Licensed Documentation If commercially available, Licensee shall have the option to require the Contractor to deliver, at Contractor’s expense: (i) one (1) hard copy and one (1) master electronic copy of the Documentation in a mutually agreeable format; (ii) based on hard copy instructions for access by downloading from the Internet
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Model coordination shall occur at all reviews during the Construction Documents Phase as identified in the BIM Execution Plan. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved. 1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract. 1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project. 1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development. 1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments. 1.4.8 The Architect/Engineer shall provide a list of all manufacturer warranties and submittals that are required by their specification. 1.4.9 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Construction Documents Phase Services 3.4.1 Based on the Owner’s approval of the Design Development Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner’s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that, in order to perform the Work, the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4.
Source Documentation Accounting records must be supported by such source documentation as canceled checks, bank statements, invoices, paid bills, donor letters, time and attendance records, activity reports, travel reports, contractual and consultant agreements, and subaward documentation. All supporting documentation should be clearly identified with the Award and general ledger accounts which are to be charged or credited. (i) The documentation standards for salary charges to grants are prescribed by 2 CFR 200.430, and in the cost principles applicable to the entity’s organization (Paragraphs 7.4 through 7.7). (ii) If records do not meet the standards in 2 CFR 200.430, then Grantor may notify Grantee in PART TWO, PART THREE or Exhibit G of the requirement to submit Personnel activity reports. See 2 CFR 200.430(i)(8). Personnel activity reports shall account on an after-the-fact basis for one hundred percent (100%) of the employee's actual time, separately indicating the time spent on the grant, other grants or projects, vacation or sick leave, and administrative time, if applicable. The reports must be signed by the employee, approved by the appropriate official, and coincide with a pay period. These time records should be used to record the distribution of salary costs to the appropriate accounts no less frequently than quarterly. (iii) Formal agreements with independent contractors, such as consultants, must include a description of the services to be performed, the period of performance, the fee and method of payment, an itemization of travel and other costs which are chargeable to the agreement, and the signatures of both the contractor and an appropriate official of Grantee. (iv) If third party in-kind (non-cash) contributions are used for Grant purposes, the valuation of these contributions must be supported with adequate documentation.
Product Documentation You should review the policy documents carefully to ensure they accurately reflect the cover, conditions, limits and other terms that you require. Particular attention should be paid to policy conditions and warranties as failure to comply with these could invalidate your policy. Claims can arise, under certain types of insurance contract, long after the expiry of the policy. It is therefore important that you retain and keep safely all documents associated with your policy.
Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Single Collective Agreement a) Central terms and local terms shall together constitute a single collective agreement.
Construction Documents Phase Bidding or Negotiation Phase:
Remittance Reports; P&I Advances (a) On the 15th day of each calendar month (or, if such 15th day is not a Business Day, then on the next succeeding Business Day), the Servicer shall furnish to the Securities Administrator a monthly remittance advice to the Securities Administrator in a format as mutually agreed to between the Servicer and the Securities Administrator, containing such information regarding the Mortgage Loans as needed by the Securities Administrator to perform its duties as set forth in Section 4.01 hereof. No later than three Business Days after the 15th day of each calendar month, the Servicer shall furnish to the Securities Administrator a monthly report containing such information regarding prepayments of Mortgage Loans during the applicable Prepayment Period in a format as mutually agreed to between the Servicer and the Securities Administrator. (b) The amount of P&I Advances to be made by the Servicer for any Distribution Date shall equal, subject to Section 4.03(d), the sum of (i) the aggregate amount of Monthly Payments (with each interest portion thereof net of the Servicing Fee), due on the related Due Date in respect of the Mortgage Loans, which Monthly Payments were Delinquent as of the close of business on the related Determination Date, plus (ii) with respect to each REO Property, which REO Property was acquired during or prior to the calendar month preceding the month of such Distribution Date and as to which such REO Property an REO Disposition did not occur during the calendar month preceding the month of such Distribution Date, an amount equal to the excess, if any, of the Monthly Payments (with each interest portion thereof net of the Servicing Fee) that would have been due on the related Due Date in respect of the related Mortgage Loans, over the net income from such REO Property transferred to the Distribution Account pursuant to Section 3.23 for distribution on such Distribution Date; provided however, that with respect to any Balloon Loan that is delinquent on its maturity date, a Servicer will not be required to advance the related balloon payment but will be required to continue to make advances in accordance with this Section 4.03 with respect to such Balloon Loan in an amount equal to an assumed Monthly Payment that would otherwise be due based on the original amortization schedule for that Mortgage Loan (with interest at the Mortgage Rate less the Servicing Fee Rate). On or before 4:00 p.m. New York time on the Servicer Remittance Date, the Servicer shall remit in immediately available funds to the Collection Account for inclusion in Available Funds an amount equal to the aggregate amount of P&I Advances, if any, to be made in respect of the Mortgage Loans and REO Properties for the related Distribution Date either (i) from its own funds or (ii) from the Collection Account, to the extent of funds held therein for future distribution (in which case, it will cause to be made an appropriate entry in the records of the Collection Account that amounts held for future distribution have been, as permitted by this Section 4.03, used by the Servicer in discharge of any such P&I Advance) or (iii) in the form of any combination of (i) and (ii) aggregating the total amount of P&I Advances to be made by the Servicer with respect to the Mortgage Loans and REO Properties. Any amounts held for future distribution and so used shall be appropriately reflected in the Servicer’s records and replaced by the Servicer by deposit in the Collection Account on or before the next succeeding Servicer Remittance Date on which such funds would be due. Nothing in this Section 4.03(b) shall be construed to prohibit the Servicer from reimbursing itself at any time from the Collection Account to the extent provided in Section 3.11 herein. (c) The obligation of the Servicer to make such P&I Advances is mandatory, notwithstanding any other provision of this Agreement but subject to (d) below, and, with respect to any Mortgage Loan or REO Property, shall continue until a Final Recovery Determination in connection therewith or the removal thereof from the Trust Fund pursuant to any applicable provision of this Agreement, except as otherwise provided in this Section. (d) Notwithstanding anything herein to the contrary, no P&I Advance or Servicing Advance shall be required to be made hereunder by the Servicer if such P&I Advance or Servicing Advance would, if made, constitute a Nonrecoverable P&I Advance or Nonrecoverable Servicing Advance. The determination by the Servicer that it has made a Nonrecoverable P&I Advance or a Nonrecoverable Servicing Advance or that any proposed P&I Advance or Servicing Advance, if made, would constitute a Nonrecoverable P&I Advance or a Nonrecoverable Servicing Advance, respectively, shall be evidenced by an Officers’ Certificate of the Servicer delivered to the Depositor, the Securities Administrator and the Trustee. In addition, the Servicer shall not be required to advance Relief Act Interest Shortfalls.
Acquisition Documents Borrower shall fully perform in all material respects all of its obligations under all Acquisition Documents, and shall enforce all of its rights and remedies thereunder as it deems appropriate in its reasonable business judgment; provided, however, that Borrower shall not take any action or fail to take any action which would result in a waiver or other loss of any material right or remedy of Borrower thereunder. Without limiting the generality of the foregoing, Borrower shall take all action necessary or appropriate to permit, and shall not take any action which would have a Material Adverse Effect upon, the full enforcement of all indemnification rights under all the Acquisition Documents. Borrower shall not, without Administrative Agent's prior written consent, modify, amend, supplement, compromise, satisfy, release or discharge any material provision of the Acquisition Documents, any material collateral securing the same, any Person liable directly or indirectly with respect thereto, or any material agreement relating to the Acquisition Documents or the collateral therefor. Borrower shall notify Administrative Agent in writing promptly after Borrower becomes aware thereof, of any event or fact which could give rise to a claim by it for indemnification under any of the Acquisition Documents to the extent such claims in the aggregate exceed $100,000.00, and shall diligently pursue such right and report to Administrative Agent on all further developments with respect thereto. If an Event of Default then exists, Borrower shall remit directly to Administrative Agent, for application to the Loan Obligations in such order as Administrative Agent determines, all amounts received by Borrower as indemnification or otherwise pursuant to the Acquisition Documents. If Borrower fails after Administrative Agent's demand to pursue diligently any right under any of the Acquisition Documents, or if an Event of Default then exists, then Administrative Agent may directly enforce such right in its own or Borrower's name and may enter into such settlements or other agreements with respect thereto as Administrative Agent determines. Notwithstanding the foregoing, Borrower shall at all times remain liable to observe and perform all of its duties and obligations under all the Acquisition Documents, and Administrative Agent's exercise of any of its rights with respect to the Collateral shall not release Borrower from any of such duties or obligations. Administrative Agent shall not be obligated to perform or fulfill any of Borrower's duties or obligations under any of the Acquisition Documents or to make any payment thereunder, or to make any inquiry as to the sufficiency of any payment or property received by it thereunder or the sufficiency of performance by any party thereunder, or to present or file any claim, or to take any action to collect or enforce any performance or payment of any amounts, or any delivery of any property.
