Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.
Contract Modifications It is understood that changes are inherent in operations of the type covered by this contract. The number of changes, the scope of those changes, and the impact they have on the progress of the original operations cannot be defined at this time. The PURCHASER is notified that changes are anticipated and that there will be no compensation made to the PURCHASER directly related to the number of changes made. Each change will be evaluated for extension of contract time and increase or decrease in compensation based on its own merit. STATE reserves the right to make, at any time during the contract, such modifications as are necessary or desirable; provided such modifications shall not change the character of the operations to be done nor increase the cost, unless such operations or cost increase is approved in writing by PURCHASER. Any modifications so made shall not invalidate this contract nor release PURCHASER of obligations under the performance bond. PURCHASER agrees to do the modified operations as if it had been a part of the original contract. If any change under this section causes an increase or decrease in the PURCHASER's cost of, or the time required for the performance of any part of the operations, the PURCHASER must submit a written statement setting forth the nature and specific extent of the claim. Such claim shall include all time and cost impacts against the contract and be submitted as soon as possible, but no later than 30 days after receipt of any written notice of modification of the contract. If the PURCHASER discovers site conditions which differ materially from what was represented in the contract or from conditions that would normally be expected to exist and be inherent to the activities defined in the contract, the PURCHASER shall notify the STATE's Authorized Representative immediately and before the area has been disturbed. The STATE's Authorized Representative will investigate the area and make a determination as to whether or not the conditions differ materially from either the conditions stated in the contract or those which could reasonably be expected in execution of this particular contract. If it is determined that a differing site condition exists, any compensation or credit will be determined based on an analysis by STATE's Authorized Representative. If the PURCHASER does not concur with the decision of the STATE's Authorized Representative and/or believes that it is entitled to additional compensation, the PURCHASER may proceed to file a claim. All claims shall be submitted in writing and shall include a detailed, factual statement of the basis of the claim, pertinent dates, contract provisions which support or allow the claim, reference to or copies of any documents which support the claim, the exact dollar value of the claim, and specific time extension requested for the claim. If the claim involves operations to be completed by subcontractors, the PURCHASER will analyze and evaluate the merits of the subcontractor's claim. PURCHASER shall forward the subcontractor's claim and PURCHASER's evaluation of such claim to STATE's Authorized Representative. The STATE's Authorized Representative will not consider direct claims from subcontractors, suppliers, manufacturers, or others not a party to this contract. The decision of the STATE shall be final and binding unless the PURCHASER requests mediation.
Cost Modifications The parties may agree to a reduction in the cost of the Contract at any time during which the Contract is in effect. Without intending to impose a limitation on the nature of the reduction, the reduction may be to hourly, staffing or unit costs, the total cost of the Contract or the reduction may take such other form as the State deems to be necessary or appropriate.
Attachment A, Scope of Services The scope of services is amended as follows:
Integration; Modification This Construction Services Agreement represents the entire understanding of District and Contractor as to those matters contained herein, and supersedes and cancels any prior oral or written understanding, promises or representations with respect to those matters covered herein, and it shall not be amended, altered or changed except by a written agreement signed by the parties hereto.
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Agreement Modifications No waiver, alteration or modification of any of the provisions of this Construction Services Agreement shall be binding upon either District or Contractor unless the same shall be in writing and signed by both District and Contractor.
SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.
Amendments; Modifications This Agreement may not be modified, altered or amended except by an agreement in writing executed by all of the parties hereto.
Service Level Agreements If a Service or a Plan includes a Service Level Agreement (SLA): (a) we are liable for any remedy or rebate specified by the SLA; and (b) subject to clauses 40 to 42, and to the express terms of the SLA, our liability for breach of the SLA is limited to such remedy or rebate.