Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.
Certain Rules Relating to the Payment of Additional Amounts (a) Upon the request, and at the expense of the Borrower, each Lender and Agent to which the Borrower is required to pay any additional amount pursuant to Subsection 4.10 or 4.11, and any Participant in respect of whose participation such payment is required, shall reasonably afford the Borrower the opportunity to contest, and reasonably cooperate with the Borrower in contesting, the imposition of any Non-Excluded Tax giving rise to such payment; provided that (i) such Lender or Agent shall not be required to afford the Borrower the opportunity to so contest unless the Borrower shall have confirmed in writing to such Lender or Agent its obligation to pay such amounts pursuant to this Agreement and (ii) the Borrower shall reimburse such Lender or Agent for its reasonable attorneys’ and accountants’ fees and disbursements incurred in so cooperating with the Borrower in contesting the imposition of such Non-Excluded Tax; provided, however, that notwithstanding the foregoing no Lender or Agent shall be required to afford the Borrower the opportunity to contest, or cooperate with the Borrower in contesting, the imposition of any Non-Excluded Taxes, if such Lender or Agent in its sole discretion in good faith determines that to do so would have an adverse effect on it.
Withholding; No Additional Amounts; Tax Event and Redemption All amounts due on this Note will be made without any applicable withholding or deduction for or on account of any present or future taxes, duties, levies, assessments or other governmental charges of whatever nature imposed or levied by or on behalf of any governmental authority, unless such withholding or deduction is required by law. Unless otherwise specified on the face hereof, the Trust will not pay any additional amounts to the Holder of this Note in respect of such withholding or deduction, any such withholding or deduction will not give rise to an event of default or any independent right or obligation to redeem this Note and the Holder will be deemed for all purposes to have received cash in an amount equal to the portion of such withholding or deduction that is attributable to such Holder’s interest in this Note as equitably determined by the Trust.
Reports; Payment of Royalty During the Term following the First Commercial Sale of a Product, Merck shall furnish to Ambrx a quarterly written report for the Calendar Quarter showing the Net Sales of all Royalty Products subject to royalty payments sold by Merck and its Related Parties in the Territory for use in the Field during the reporting period and the royalties payable under this Agreement. Reports shall be due on the [***] day following the close of each Calendar Quarter. Royalties shown to have accrued by each royalty report shall be due and payable on the date such royalty report is due. Merck shall keep complete and accurate records in sufficient detail to enable the royalties payable hereunder to be determined.
Payments Free of Taxes; Obligation to Withhold; Payments on Account of Taxes (i) Any and all payments by or on account of any obligation of any Loan Party under any Loan Document shall be made without deduction or withholding for any Taxes, except as required by applicable Laws. If any applicable Laws (as determined in the good faith discretion of the Administrative Agent) require the deduction or withholding of any Tax from any such payment by the Administrative Agent or a Loan Party, then the Administrative Agent or such Loan Party shall be entitled to make such deduction or withholding, upon the basis of the information and documentation to be delivered pursuant to subsection (e) below.
Procedure for Payment of Indemnifiable Amounts Indemnitee shall submit to the Company a written request specifying the Indemnifiable Amounts for which Indemnitee seeks payment under Section 3 of this Agreement and the basis for the claim. The Company shall pay such Indemnifiable Amounts to Indemnitee within twenty (20) calendar days of receipt of the request. At the request of the Company, Indemnitee shall furnish such documentation and information as are reasonably available to Indemnitee and necessary to establish that Indemnitee is entitled to indemnification hereunder.
Indemnification and Reimbursement of Payments on Behalf of Executive The Company, Employer and their respective Subsidiaries shall be entitled to deduct or withhold from any amounts owing from the Company or any of its Subsidiaries to Executive any federal, state, local or foreign withholding taxes, excise taxes, or employment taxes (“Taxes”) imposed with respect to Executive’s compensation or other payments from the Company or any of its Subsidiaries or Executive’s ownership interest in the Company, including, without limitation, wages, bonuses, dividends, the receipt or exercise of equity options and/or the receipt or vesting of restricted equity. In the event the Company or its Subsidiaries does not make such deductions or withholdings, Executive shall indemnify the Company and its Subsidiaries for any amounts paid with respect to any such Taxes, together with any interest, penalties and related expenses thereto.
