Common use of Settlement of Disputes by Arbitration Clause in Contracts

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be final. But if the vendor is dissatisfied with Bank’s decision, the Contractor may, within 28 days after receiving notice of such decision, give a written notice to the Bank requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in dispute. If both the parties agree, a sole arbitrator would be appointed for the purpose by the Bank in consultation with the vendor. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within the period specified under the Arbitration and Conciliation Act, 1996, from the date of entering upon the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including the fees of arbitral tribunal shall be governed by the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunder. The venue of arbitration shall be RBI, Chennai. This submission shall be deemed to be a submission to arbitration within the meaning of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank and the Contractor hereby also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.

Appears in 2 contracts

Samples: Annual Service Contract, Annual Service Contract

AutoNDA by SimpleDocs

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be finalfinal and without appeal. But if the vendor is dissatisfied with Bank’s decision, either the Contractor may, be dissatisfied on any matter the Contractor may within 28 days after receiving notice of such decision, decision give a written notice to the Bank other party requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in disputedispute or difference of which such written notice has been given. If both the parties agree, agree a sole single arbitrator would be appointed for the purpose by the Bank in consultation with the vendorpurpose. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding one more person to act as third arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice notice, save in regard to the excepted matters, referred to in the preceding clause, and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within one year (or such further extended time as may be decided by him or them as the period specified under case may be with the Arbitration and Conciliation Act, 1996, consent of the parties) from the date of entering upon on the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including Upon any such reference, the fees of arbitral tribunal decision on the cost incidental to the reference and award respectively shall be governed in the discretion of the arbitrator or arbitrators as the case may be., who may determine the amount thereof or direct the same to be taxed as between the party and party, and shall direct by whom and to whom and in what manner the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunder. The venue of arbitration same shall be RBI, Chennaiborne and paid. This submission shall be deemed to be a submission to arbitration within the meaning of the Indian Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank Employer and the Contractor hereby also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.. I / We hereby declare that I / we have read and understood the above instructions for guidance of tenderers. Date: Place: Signature of tenderer with seal. Name and Address:

Appears in 1 contract

Samples: Maintenance Contract

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be final. But if the vendor is dissatisfied with Bank’s decision, either the Contractor may, be dissatisfied on any matter the Contractor may within 28 days after receiving notice of such decision, decision give a written notice to the Bank other party requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in disputedispute or difference of which such written notice has been given. If both the parties agree, a agree sole arbitrator would be appointed for the purpose by the Bank in consultation with the vendorpurpose. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice notice, save in regard to the excepted matters, referred to in the preceding clause, and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within the period specified under the Arbitration and Conciliation Act, 1996, from the date of entering upon the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including the fees of arbitral tribunal shall be governed by the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunder. The venue of arbitration shall be RBI, ChennaiPatna. This submission shall be deemed to be a submission to arbitration within the meaning of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank and the Contractor hereby also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.

Appears in 1 contract

Samples: Annual Service Contract

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be final. But if the vendor is dissatisfied with Bank’s decision, either the Contractor may, be dissatisfied on any matter the Contractor may within 28 days after receiving notice of such decision, decision give a written notice to the Bank other party requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in disputedispute or difference of which such written notice has been given. If both the parties agree, a agree sole arbitrator would be appointed for the purpose by the Bank in consultation with the vendorpurpose. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice notice, save in regard to the excepted matters, referred to in the preceding clause, and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within the period specified under the Arbitration and Conciliation Act, 1996, from the date of entering upon the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including the fees of arbitral tribunal shall be governed by the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunderthere under. The venue of arbitration shall be RBI, ChennaiBhopal. This submission shall be deemed to be a submission to arbitration within the meaning of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank and the Contractor hereby also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract. All disputes arising shall be subject to the exclusive jurisdiction of competent court at Bhopal.

Appears in 1 contract

Samples: Annual Maintenance Contract

AutoNDA by SimpleDocs

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be final. But if the vendor is dissatisfied with Bank’s decision, either the Contractor may, be dissatisfied on any matter the Contractor may within 28 days after receiving notice of such decision, decision give a written notice to the Bank other party requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in disputedispute or difference of which such written notice has been given. If both the parties agree, a agree sole arbitrator would be appointed for the purpose by the Bank in consultation with the vendorpurpose. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice notice, save in regard to the excepted matters, referred to in the preceding clause, and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within the period specified under the Arbitration and Conciliation Act, 1996, from the date of entering upon the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including the fees of arbitral tribunal shall be governed by the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunder. The venue of arbitration shall be RBI, ChennaiGuwahati. This submission shall be deemed to be a submission to arbitration within the meaning of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank and the Contractor hereby also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.

Appears in 1 contract

Samples: Annual Maintenance and Catering Contract

Settlement of Disputes by Arbitration. All disputes and differences of any kind whatever arising out of or in connection with the contract or the carrying out of the works (whether during the progress of the works or after their completion and whether before or after the determination abandonment or breach of the contract) shall be referred to and settled by the Bank who shall state its decision in writing. Such decision may be in the form of a final certificate or otherwise. The decision of the Bank with respect to any of the excepted matters shall be final. But if the vendor is dissatisfied with Bank’s decision, the Contractor may, within 28 days after receiving notice of such decision, give a written notice to the Bank requiring that the matters in dispute be arbitrated upon. Such written notice shall specify the matters, which are in dispute. If both the parties agree, a sole arbitrator would be appointed for the purpose by the Bank in consultation with the vendor. In case no agreement could be reached on the appointment of single arbitrator, both the parties will nominate one person each as an arbitrator on their behalf. The two arbitrators nominated by the parties shall nominate presiding arbitrator or umpire. The arbitrator or arbitrators, as the case may be, shall have power to open up, review and revise any certificate, opinion, decision, requisition or notice and to determine all matters to dispute which shall be submitted to arbitration and of which notice shall have been given as aforesaid. The arbitrator or arbitrators, as the case may be, shall make his or their award within the period specified under the Arbitration and Conciliation Act, 1996, from the date of entering upon the reference. In case during the arbitration proceedings the parties mutually settle or compromise their dispute or difference, on the parties filing their joint memorandum of the settlement or compromise, the arbitrator or the arbitrators as the case may be, shall make an award in terms of such settlement or compromise. The arbitration proceedings including the fees of arbitral tribunal shall be governed by the provisions of Arbitration and Conciliation Act, 1996 and the rules made thereunder. The venue of arbitration shall be RBI, Chennai. This submission shall be deemed to be a submission to arbitration within the meaning of the Arbitration and Conciliation Act, 1996 or any statutory modification thereof. The award of the arbitrator or arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being referred to arbitration, but shall proceed with the works with all due diligence and shall until the decision of the arbitrator or arbitrators is given, abide by the decision of the Bank. No award of the arbitrator or arbitrators, as the case may be, shall relieve the Contractor of his obligations to adhere strictly to the Bank's instructions with regard to the actual carrying out of the works. The Bank and the Contractor hereby xxxxxx also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.

Appears in 1 contract

Samples: Annual Service Contract

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!