Shared Facilities The Parties acknowledge and agree that certain of the Shared Facilities and Interconnection Facilities, and Seller’s rights and obligations under the Interconnection Agreement, may be subject to certain shared facilities and/or co-tenancy agreements to be entered into among Seller, the Transmission Provider, Seller’s Affiliates, and/or third parties pursuant to which certain Interconnection Facilities may be subject to joint ownership and shared maintenance and operation arrangements; provided, such agreements (i) shall permit Seller to perform or satisfy, and shall not purport to limit, its obligations hereunder, and (ii) provide for separate metering of the Facility.
Verizon OSS Facilities Any gateways, interfaces, databases, facilities, equipment, software, or systems, used by Verizon to provide Verizon OSS Services to CBB.
Laundry Facilities Washers and dryers are installed in each apartment for the exclusive use of students in the apartment. Any other use is prohibited. The use of washers and dryers are free. LINEN: Brighton provides a mattress cover on all mattresses. Students need to bring their own bedding. All beds are regular twin size. The typical cost for replacing a mattress cover is $25.00. MAINTENANCE: Students are responsible to notify the manager in writing as soon as possible if they notice anything in an apartment that requires repair work or maintenance. See “Property Conditions” section 12 of the BYU-Idaho Student Landlord Housing Contract.
Common Facilities Common Facilities" (sometimes referred to herein as "Common Areas") means all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Center and their employees, agents, customers and other invitees, including without limitation, if the same exist: building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Center, and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord reserves the right to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time without liability to Tenant. Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to close all or any portion of the Common Facilities to such extent; to close temporarily all or any portion of the Common Facilities for any reason, including for the purpose of preventing a dedication thereof or the accrual of any rights to any person or the public therein; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, all Common Facilities not within the Premises, which Tenant may use under a revocable license, on a nonexclusive basis in common with other tenants, and if any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirteen Thousand, Six Hundred Thirty-Two Dollars ($13,632.00). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items.
Property Management Fee For its services in managing the day-to-day operations of the Property in accordance with the terms of this Agreement, Company shall pay to Property Manager an annual property management fee (the “Property Management Fee”) equal to 4.0% of the Gross Revenue (as hereinafter defined). The Property Management Fee shall be prorated for any partial year and shall be payable in equal monthly installments, in advance. The Property Management Fee shall be payable on the first day of each month from the Operating Account or from other funds timely provided by the Company. Upon the expiration or earlier termination of this Agreement, the parties will prorate the Property Management Fee on a daily basis to the effective date of such expiration or termination. For purposes of this Agreement, the term “Gross Revenue” shall mean all gross collections from the operations of the Property, including, without limitation, rental receipts, late fees, application fees, pet fees, damages, lease buy-out payments, reimbursements by Tenants for common area expenses, operating expenses and taxes and similar pass-through obligations paid by Tenants, but shall expressly exclude (i) security deposits received from Tenants and interest accrued thereon for the benefit of the Tenants until such deposits or interest are included in the taxable income of the Company; (ii) advance rents (but not lease buy-out payments) until the month in which payments are to apply as rental income; (iii) reimbursements by Tenants for work done for a particular Tenant; (iv) proceeds from the sale or other disposition of all or any portion of the Property; (v) insurance proceeds received by the Company as a result of any insured loss (except proceeds from rent insurance or the excess of insurance proceeds for repairs over the actual costs of such repairs); (vi) condemnation proceeds not attributable to rent; (vii) capital contributions made by the Company; (viii) proceeds from capital, financing and any other transactions not in the ordinary course of the operation of the Property; (ix) income derived from interest on investments or otherwise; (x) abatement of taxes, awards arising out of takings by eminent domain and discounts and dividends on insurance policies; and (xi) rental concessions not paid by third parties.
Construction Costs Under no circumstances shall the Consultant be liable for extra costs or other consequences due to unknown conditions or related to the failure of contractors to perform work in accordance with the plans and specifications. Consultant shall have no liability whatsoever for any costs arising out of the Client’s decision to obtain bids or proceed with construction before the Consultant has issued final, fully-approved plans and specifications. The Client acknowledges that all preliminary plans are subject to substantial revision until plans are fully approved and all permits obtained.
As-Built Drawings Within thirty (30) Days of the successful completion of the Acceptance Test, Seller shall provide for Company review a set of the proposed as‑built drawings for the Company-Owned Interconnection Facilities constructed by Seller (and/or its Contractors). Within thirty (30) Days of Company's receipt of the proposed as‑built drawings, Company shall provide Seller with either (i) its comments on the proposed as‑built drawings or (ii) notice of acceptance of the proposed as‑built drawings as final as‑built drawings. If Company provides comments on the proposed as‑built drawings, Seller shall incorporate such comments into a final set of as‑built drawings and provide such final as‑built drawings to Company within twenty (20) Days of Seller's receipt of Company's comments.
Refinancing Facilities (a) On one or more occasions after the Effective Date, the Borrower may obtain, from any Lender or any other bank, financial institution or other institutional lender or investor that agrees to provide any portion of Refinancing Term Loans pursuant to a Refinancing Amendment in accordance with this Section 2.22 (each, an “Additional Refinancing Lender”) (provided that the Administrative Agent shall have consented (such consent not to be unreasonably withheld, conditioned or delayed) to such Lender’s or Additional Refinancing Lender’s making such Refinancing Term Loans to the extent such consent, if any, would be required under Section 9.04(b) for, and to the extent that such Additional Refinancing Lender is a Purchasing Borrower Party or an Affiliated Lender, the requirements of Section 9.04(g) and 9.04(f), respectively, shall be satisfied as if such Refinancing Term Loan were, an assignment of Term Loans to such Lender or Additional Refinancing Lender), Credit Agreement Refinancing Indebtedness in respect of all or any portion of Term Loans then outstanding under this Agreement, in the form of Refinancing Term Loans or Refinancing Term Commitments pursuant to a Refinancing Amendment; provided that no Lender is obligated hereunder to provide such Credit Agreement Refinancing Indebtedness.
(b) The effectiveness of any Refinancing Amendment shall be subject to the satisfaction on the date thereof of each of the conditions set forth in Section 4.02 and, to the extent reasonably requested by the Administrative Agent, receipt by the Administrative Agent of (i) customary legal opinions, board resolutions and officers’ certificates consistent with those delivered on the Effective Date other than changes to such legal opinion resulting from a change in law, change in fact or change to counsel’s form of opinion reasonably satisfactory to the Administrative Agent and (ii) reaffirmation agreements and/or such amendments to the Security Documents as may be reasonably requested by the Administrative Agent in order to ensure that such Credit Agreement Refinancing Indebtedness is provided with the benefit of the applicable Loan Documents.
(c) Each issuance of Credit Agreement Refinancing Indebtedness under Section 2.22(a) shall be in an aggregate principal amount that is (x) not less than $50,000,000 and (y) an integral multiple of $10,000,000 in excess thereof.
(d) Each of the parties hereto hereby agrees that this Agreement and the other Loan Documents may be amended pursuant to a Refinancing Amendment, without the consent of any other Lenders, to the extent (but only to the extent) necessary to (i) reflect the existence and terms of the Credit Agreement Refinancing Indebtedness incurred pursuant thereto and (ii) effect such other amendments to this Agreement and the other Loan Documents as may be necessary or appropriate, in the reasonable opinion of the Administrative Agent and the Borrower, to effect the provisions of this Section 2.22, including any amendments necessary to treat the applicable Loans and/or Commitments established under the Refinancing Amendment as a new Class of Loans and/or Commitments hereunder, and the Lenders hereby expressly authorize the Administrative Agent to enter into any such Refinancing Amendment.
(e) This Section 2.22 shall supersede any provisions in Section 2.17 or Section 9.02 to the contrary solely to the extent provided in this Section 2.22.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.