Indemnification for Third Party Claims
(a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents.
(b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents.
(c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that:
(i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party;
(ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and
(iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld.
(d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement.
(e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Notice and Cooperation by Indemnitee Indemnitee shall, as a condition precedent to his/her right to be indemnified under this Agreement, give the Company notice in writing as soon as practicable of any claim made against Indemnitee for which indemnification will or could be sought under this Agreement, provided that the delay of Indemnitee to give notice hereunder shall not prejudice any of Indemnitee’s rights hereunder, unless such delay results in the Company’s forfeiture of substantive rights or defenses. Notice to the Company shall be given in accordance with Section F.7 below. If, at the time of receipt of such notice, the Company has directors’ and officers’ liability insurance policies in effect, the Company shall give prompt notice to its insurers of the Proceeding relating to the notice. The Company shall thereafter take all necessary and desirable action to cause such insurers to pay, on behalf of Indemnitee, all Expenses payable as a result of such Proceeding. In addition, Indemnitee shall give the Company such information and cooperation as the Company may reasonably request.
Defense by Indemnifying Party In connection with any claim giving rise to indemnity hereunder resulting from or arising out of any claim or legal proceeding by a Person who is not a party to this Agreement, the Indemnifying Party at its sole cost and expense may, upon written notice to the Indemnified Party, assume the defense of any such claim or legal proceeding (i) if it acknowledges to the Indemnified Party in writing its obligations to indemnify the Indemnified Party with respect to all elements of such claim (subject to any limitations on such liability contained in this Agreement) and (ii) if it provides assurances, reasonably satisfactory to the Indemnified Party, that it will be financially able to satisfy such claims in full if the same are decided adversely. If the Indemnifying Party assumes the defense of any such claim or legal proceeding, it may use counsel of its choice to prosecute such defense, subject to the approval of such counsel by the Indemnified Party, which approval shall not be unreasonably withheld or delayed. The Indemnified Party shall be entitled to participate in (but not control) the defense of any such action, with its counsel and at its own expense; provided, however, that if the Indemnified Party, in its sole discretion, determines that there exists a conflict of interest between the Indemnifying Party (or any constituent party thereof) and the Indemnified Party, the Indemnified Party (or any constituent party thereof) shall have the right to engage separate counsel, the reasonable costs and expenses of which shall be paid by the Indemnified Party. If the Indemnifying Party assumes the defense of any such claim or legal proceeding, the Indemnifying Party shall take all steps necessary to pursue the resolution thereof in a prompt and diligent manner. The Indemnifying Party shall be entitled to consent to a settlement of, or the stipulation of any judgment arising from, any such claim or legal proceeding, with the consent of the Indemnified Party, which consent shall not be unreasonably withheld or delayed; provided, however, that no such consent shall be required from the Indemnified Party if (i) the Indemnifying Party pays or causes to be paid all Losses arising out of such settlement or judgment concurrently with the effectiveness thereof (as well as all other Losses theretofore incurred by the Indemnified Party which then remain unpaid or unreimbursed), (ii) in the case of a settlement, the settlement is conditioned upon a complete release by the claimant of the Indemnified Party and (iii) such settlement or judgment does not require the encumbrance of any asset of the Indemnified Party or impose any restriction upon its conduct of business.
Notice/Cooperation by Indemnitee Indemnitee shall, as a condition precedent to Indemnitee's right to be indemnified or Indemnitee's right to receive Expense Advances under this Agreement, give the Company notice in writing as soon as practicable of any Claim made against Indemnitee for which indemnification will or could be sought under this Agreement. Notice to the Company shall be directed to the Chief Executive Officer of the Company at the address shown on the signature page of this Agreement (or such other address as the Company shall designate in writing to Indemnitee). In addition, Indemnitee shall give the Company such information and cooperation as it may reasonably require and as shall be within Indemnitee's power.
Third Party Claims Each Notice of Claim given by Acquiror, which involves a third party (a “Third Party Claim”), shall be resolved as follows:
(a) If, within thirty (30) days after a Notice of Claim is delivered to the Seller Representative, (x) the Seller Representative produces a notice of election and (y) such notice of election includes a written acknowledgment from the Seller Representative on behalf of the Seller Guarantors and the Sellers (the “Indemnifying Persons”) that the Indemnifying Persons would be required to indemnify the Acquiror Indemnified Persons for all Damages in connection with such Third Party Claim Notice, the Indemnifying Persons shall have the right, but not the obligation to (i) take control of the defense and investigation of such Third Party Claim, (ii) employ and engage attorneys of their own choice (subject to the approval of Acquiror, such approval not to be unreasonably withheld, conditioned or delayed) to handle and defend the same, at the Indemnifying Persons’ sole cost and expense, and (iii) compromise or settle such Third Party Claim, which compromise or settlement shall be made only with the written consent of Acquiror; provided, that such consent will not be required if such settlement includes an unconditional release of the Acquiror Indemnified Persons and provides solely for payment of monetary damages for which the Acquiror Indemnified Persons will be indemnified in full. Notwithstanding the foregoing, the Indemnifying Persons shall not have the right to assume the defense of a Third Party Claim if (1) the Indemnifying Persons fail to actively and diligently conduct the defense of the Third Party Claim (after notice and reasonable opportunity to cure), (2) the Acquiror Indemnified Persons have received advice from counsel that an actual or potential conflict exists between the Acquiror Indemnified Persons and the Indemnifying Persons in connection with the defense of such Third Party Claim, (3) such Third Party Claim seeks a finding or admission of a violation of any criminal Law by an Acquiror Indemnified Person, (4) such Third Party Claim seeks an injunction or other equitable remedies in respect of an Acquiror Indemnified Person or its business, (5) such Third Party Claim relates to a Material Customer or Material Supplier, or (6) such Third Party Claim is reasonably likely to result in Damages that, taken with any other then existing claims under this Article 12, would not be not be fully indemnified hereunder.
(b) In the event that the Indemnifying Persons defend the Acquiror Indemnified Persons against a Third Party Claim, the Acquiror Indemnified Persons shall cooperate in all reasonable respects, at the Indemnifying Persons’ request, with the Indemnifying Persons and their attorneys in the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom, including, if appropriate and related to such Third Party Claim, in making any counterclaim against the third party claimant, or any cross complaint against any Person, in each case, at the expense of the Indemnifying Persons. The Acquiror Indemnified Persons may, at their own sole cost and expense, monitor and further participate in (but not control) the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom.
(c) Notwithstanding anything to the contrary herein, if the Indemnifying Persons do not assume such defense and investigation or does not acknowledge in writing within thirty (30) days after receipt of the Third Party Claim Notice its obligation to indemnify the Acquiror Indemnified Persons against any Damages arising from such Third Party Claim, then the Acquiror Indemnified Persons shall have the right to retain separate counsel of their choosing, defend such Third Party Claim and have the sole power to direct and control such defense (all at the cost and expense of the Indemnifying Persons if it is ultimately determined that the Acquiror Indemnified Persons are entitled to indemnification hereunder); it being understood that the Acquiror Indemnified Persons’ right to indemnification for a Third Party Claim shall not be adversely affected by assuming the defense of such Third Party Claim. Notwithstanding anything herein to the contrary, whether or not the Indemnifying Persons shall have assumed the defense of such Third Party Claim, the Acquiror Indemnified Persons shall not settle, compromise or pay such Third Party Claim for which they seeks indemnification hereunder without the prior written consent of the Indemnifying Persons, which consent shall not be unreasonably withheld, conditioned or delayed.
(d) The Acquiror Indemnified Persons and the Indemnifying Persons shall use commercially reasonable efforts to avoid production of confidential information (consistent with Law), and to cause all communications among employees, counsel and others representing any party to a Third Party Claim to be made so as to preserve any applicable attorney-client or work-product privileges.
(e) Notwithstanding anything to the contrary in this Agreement, Section 8.1(d) shall exclusively govern S Corporation Tax Proceedings.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees),
(a) based on allegations that, if true, would establish
(i) the Indemnifying Party’s breach of this Agreement;
(ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct;
(iii) the Indemnifying Party’s negligent or willful misconduct or omissions;
(iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party;
(v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or
(vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or
(b) that arises out of:
(i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement;
(ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement;
(iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement;
(iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or
(v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)).
22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section.
22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.
Successful Defense; Partial Indemnification To the extent that Indemnitee has been successful on the merits or otherwise in defense of any action, suit or proceeding referred to in Section 1 hereof or in defense of any claim, issue or matter therein, Indemnitee shall be indemnified against expenses (including attorneys’ fees) actually and reasonably incurred in connection therewith. For purposes of this Agreement and without limiting the foregoing, if any action, suit or proceeding is disposed of, on the merits or otherwise (including a disposition without prejudice), without (i) the disposition being adverse to Indemnitee, (ii) an adjudication that Indemnitee was liable to the Corporation, (iii) a plea of guilty or nolo contendere by Indemnitee, (iv) an adjudication that Indemnitee did not act in good faith and in a manner Indemnitee reasonably believed to be in or not opposed to the best interests of the Corporation, and (v) with respect to any criminal proceeding, an adjudication that Indemnitee had reasonable cause to believe Indemnitee’s conduct was unlawful, Indemnitee shall be considered for the purposes hereof to have been wholly successful with respect thereto. If Indemnitee is entitled under any provision of this Agreement to indemnification by the Corporation for some or a portion of the expenses (including attorneys’ fees), judgments, fines or amounts paid in settlement actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection with any action, suit, proceeding or investigation, or in defense of any claim, issue or matter therein, and any appeal therefrom but not, however, for the total amount thereof, the Corporation shall nevertheless indemnify Indemnitee for the portion of such expenses (including attorneys’ fees), judgments, fines or amounts paid in settlement to which Indemnitee is entitled.
Actions where Indemnitee is Deceased If the Indemnitee is a person who was or is a party or is threatened to be made a party to any proceeding by reason of the fact that he is or was an agent of the Company, or by reason of anything done or not done by him in any such capacity, and if prior to, during the pendency of after completion of such proceeding Indemnitee becomes deceased, the Company shall indemnify the Indemnitee's heirs, executors and administrators against any and all expenses and liabilities of any type whatsoever (including, but not limited to, judgments, fines, ERISA excise taxes and penalties, and amounts paid in settlement) actually and reasonably incurred to the extent Indemnitee would have been entitled to indemnification pursuant to Sections 4(a), 4(b), or 4(c) above were Indemnitee still alive.
Right of Indemnitee to Bring Suit If a claim under Section 5.4 or 5.5 is not paid in full by the Company within 60 calendar days after a written claim has been received by the Company, except in the case of a claim for an Advancement of Expenses, in which case the applicable period shall be 20 calendar days, the Indemnitee may at any time thereafter bring suit against the Company to recover the unpaid amount of the claim. If successful in whole or in part in any such suit, or in a suit brought by the Company to recover an Advancement of Expenses pursuant to the terms of an Undertaking, the Indemnitee shall be entitled to be paid also the expense of prosecuting or defending such suit. In (a) any suit brought by the Indemnitee to enforce a right to indemnification hereunder (but not in a suit brought by the Indemnitee to enforce a right to an Advancement of Expenses) it shall be a defense that, and (b) any suit brought by the Company to recover an Advancement of Expenses pursuant to the terms of an Undertaking, the Company shall be entitled to recover such expenses upon a Final Adjudication that, the Indemnitee has not met any applicable standard for indemnification set forth in the Delaware General Corporation Law as if the Company were a Delaware corporation. Neither the failure of the Company (including the Sole Member, the Managers or independent legal counsel) to have made a determination prior to the commencement of such suit that indemnification of the Indemnitee is proper in the circumstances because the Indemnitee has met any applicable standard of conduct set forth in the Delaware General Corporation Law as if the Company were a Delaware corporation, nor an actual determination by the Company (including the Sole Member, the Managers or independent legal counsel) that the Indemnitee has not met any such applicable standard of conduct, shall create a presumption that the Indemnitee has not met the applicable standard of conduct or, in the case of such a suit brought by the Indemnitee, be a defense to such
INDEMNIFICATION FOR INFRINGEMENT The terms of this Section 10 do not apply to the Community Edition Licensees. Licensor will defend or settle, at its own expense, any claim against Licensee asserting a copyright, trademark or trade secret which concerns the Product used within the scope of the Agreement hereunder. Licensor shall indemnify Licensee against any loss, expense or liability including reasonable attorney's fees from any damages alleged against Licensee. Licensor's obligations under this Section are conditioned on Licensee promptly notifying Licensor in writing after Licensee first receives notice of any such claim, action or allegation of infringement and, Licensor being given sole control of the defense of any action and all negotiations for its settlement or compromise, with the reasonable assistance of Licensee. Licensor shall not be liable for any costs or expenditures incurred by Licensee without Licensor's prior written consent. If an injunction or order is obtained against Licensee's use of the Product by reason of the allegations of infringement, or if in Licensor's opinion the Product is likely to become the subject of a claim of infringement, Licensor shall, at its expense:
(a) Procure for Licensee the right to continue using the Product; or
(b) Modify or replace the Product with a compatible, functionally equivalent, non-infringing Product(s); or
(c) If neither (a) nor (b) is reasonably practical in Licensor's judgment, remove the Product and issue Licensee a pro rata credit based upon the License fees paid for the Product prorated over a thirty-six (36) month period from the date of shipment of the Product. Thereafter, termination shall proceed in accordance with the terms of Section 4. Licensor shall have no obligation under this Section to the extent the alleged infringement results from (i) modification of the Product other than by Licensor; (ii) the combination of the Product with products not provided by Licensor; or (iii) use of any older version of the Product when use of a newer version made available to Licensee would have avoided the infringement. This Section 10 is Licensor's entire liability and Licensee's sole and exclusive remedy in the event of intellectual property infringement of any kind.
