We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Startup and Testing Sample Clauses

Startup and Testing. Prior to the Commercial Operation Date and as a condition precedent to the achievement of the Commercial Operation Date, Buyer shall have the right to (i) review and monitor the performance and achievement of all initial performance tests and all other tests required under the Facility construction contracts that must be performed in order to achieve completion; (ii) be present to witness such initial performance tests and review the results thereof; and (iii) perform such detailed examinations, inspections, quality surveillance and tests as, in the judgment of Buyer, are appropriate and advisable to determine that all components of the Facility have been installed in accordance with this Agreement.
Sample 1Sample 2Sample 3See All (7)
Startup and Testing. Before the Commercial Operation Date, Buyer shall have the right, during normal working hours and subject to Seller’s or its Subcontractors’ reasonable requirements and procedures in respect of confidentiality and safety: (i) to review and monitor the results of all initial performance tests and all other tests required under the Facility construction contracts that must be performed in order to achieve completion; and (ii) to be present to witness such initial performance tests and review the results thereof.
Sample 1Sample 2
Startup and Testing. Prior to each of the (i) Partial Commercial Operation Date and (ii) Full Commercial Operation Date, during reasonable working hours and subject to Seller’s or its contractors’ or subcontractors’ reasonable requirements and procedures in respect of confidentiality and safety, Seller shall provide Buyer with notice and a reasonable opportunity to: (i) review and monitor the contractors’ performance and achievement of all initial performance tests and all other tests that must be performed in order to achieve any Milestone, as applicable, and the result of such tests, with respect to which Seller shall provide to Buyer a schedule for the performance of such tests at least ten (10) Business Days before such tests are scheduled to begin; (ii) be present to witness such initial performance tests and review the results thereof; and (iii) perform such detailed examinations, inspections, quality surveillance and tests as, in the judgment of Buyer, are appropriate and advisable to determine that the Facility equipment and all ancillary components of the Facility have been installed in accordance with this Agreement and the Facility construction contracts, the Requirements; provided that such examinations, inspections, quality surveillance and tests shall not interfere with the operations of the Facility or Seller’s or its contractors’ or subcontractors’ work.
Sample 1
Startup and Testing. Upon delivery and installation of each Reactor Skid Unit at the Site Location and prior to any testing or start-up of such Unit, Licensee and Site User shall examine the Unit to determine its physical condition and operational status, and its conformity to the Licensor’s Process Design Package, and shall conduct such testing of the Unit as shall be required to determine that it is operational and functional. Licensee shall provide Licensee with at least seven (7) days advance notice of any scheduled inspection and testing in order to give Licensor an opportunity to travel to the Site Location and participate in such inspection and testing.
Sample 1
Startup and Testing. Prior to the Commercial Operation Date, Buyer shall have the right to: (a) review and monitor (at the Site) the contractors’ performance and achievement of all initial performance tests during Facility start-up, and all other material tests required under the Facility construction contracts performed to achieve any Milestone, and Seller shall, or shall cause its contractor to provide at least ten (10) Business Days to Buyer before any such test begins; (b) be present to witness such initial performance tests and review the results thereof; and (c) perform such detailed examinations, inspections, quality surveillance and tests as, in the judgment of Buyer, are appropriate and advisable to determine that the Facility equipment and all ancillary components of the Facility have been installed in accordance with the Facility construction contracts and the Requirements, provided that Buyer may not unreasonably interfere with any Site activities of Seller or Seller’s contractors, or Seller’s timely achievement of COD.
Sample 1
Startup and Testing. ‌ Seller shall coordinate with Buyer a schedule for testing of Seller's plant, and Seller shall not cause any disruption of Buyer's operations. Seller shall be responsible for all fuel costs associated with any use of Seller's plant before the Commercial Operation Date. Buyer shall not be responsible to pay for any steam produced by Seller's plant before the Commercial Operation Date. The Testing shall include all steps necessary to allow Buyer to determine that the steam delivered by Seller meets the specifications set forth on Schedule 1 and is otherwise reasonably satisfactory to Buyer. Upon request, Seller shall provide Buyer with a copy of the results of any testing.
Sample 1
Startup and Testing. Prior to the Commercial Operation Date, Seller shall provide to Buyer the opportunity at Buyer’s sole expense and without interfering with Seller’s activities at the Facility to:‌ (a) review and monitor the contractors’ performance and achievement of all initial performance tests and all other tests required under the Facility construction contracts performed to achieve any Milestone, and Seller shall, or shall cause its contractor to provide at least ten (10) Business Days to Buyer before any such test begins; provided that Buyer shall at all times comply with Seller’s or the contractor’s safety and security requirements when present at the Facility; (b) be present to witness such initial performance tests and review the results thereof; provided that Buyer shall at all times comply with Seller’s or the contractor’s safety and security requirements when present at the Facility; and (c) perform such detailed examinations, inspections, quality surveillance, and tests as are appropriate and advisable to determine that the Facility equipment and all ancillary components of the Facility have been installed in accordance with the Facility construction contracts and the Requirements.
Sample 1
Startup and Testing. Prior to the Commercial Operation Date and as a condition precedent to the achievement of the Commercial Operation Date, Buyer shall have the right to: (i) review and monitor the contractors’ performance and achievement of all initial performance tests and all other tests required under the Facility construction contracts that must be performed in order to achieve completion, with respect to which the construction contracts shall provide that at least ten (10) Business Days before such tests begin the contractors shall deliver to Buyer a schedule for the performance of such tests; (ii) be present to witness such initial performance tests and review the results thereof; and (iii) perform such detailed examinations, inspections, quality surveillance and tests as, in the reasonable judgment of Buyer, are appropriate and advisable to determine that the Facility equipment and all ancillary components of the Facility have been installed in accordance with this Agreement and the Facility construction contracts, all applicable standards, Prudent Utility Practices, Requirements of Law, and Seller’s Quality Assurance Program.
Sample 1

Related to Startup and Testing

  • Meter Testing Company shall provide at least twenty-four (24) hours' notice to Seller prior to any test it may perform on the revenue meters or metering equipment. Seller shall have the right to have a representative present during each such test. Seller may request, and Company shall perform, if requested, tests in addition to the every fifth-year test and Seller shall pay the cost of such tests. Company may, in its sole discretion, perform tests in addition to the fifth year test and Company shall pay the cost of such tests. If any of the revenue meters or metering equipment is found to be inaccurate at any time, as determined by testing in accordance with this Section 10.2 (Meter Testing), Company shall promptly cause such equipment to be made accurate, and the period of inaccuracy, as well as an estimate for correct meter readings, shall be determined in accordance with Section 10.3 (Corrections).

  • Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.

  • Substance Abuse Testing The Parties agree that it is in the best interest of all concerned to promote a safe working environment. The Union has no objection to pre-employment substance abuse testing when required by the Employer and further, the Union has no objection to voluntary substance abuse testing to qualify for employment on projects when required by a project owner. The cost and scheduling of such testing shall be paid for and arranged by the Employer. The Union agrees to reimburse the Employer for any failed pre-access Alcohol and Drug test costs.

  • Random Testing Notwithstanding any provisions of the Collective Agreement or any special agreements appended thereto, section 4.6 of the Canadian Model will not be applied by agreement. If applied to a worker dispatched by the Union, it will be applied or deemed to be applied unilaterally by the Employer. The Union retains the right to grieve the legality of any imposition of random testing in accordance with the Grievance Procedure set out in this Collective Agreement.

  • ODUF Testing 6.6.1 Upon request from TWTC, AT&T shall send ODUF test files to TWTC. The Parties agree to review and discuss the ODUF file content and/or format. For testing of usage results, AT&T shall request that TWTC set up a production (live) file. The live test may consist of TWTC’s employees making test calls for the types of services TWTC requests on ODUF. These test calls are logged by TWTC, and the logs are provided to AT&T. These logs will be used to verify the files. Testing will be completed within thirty (30) days from the date on which the initial test file was sent.

  • Audit and Testing 4.1 The Contractor shall conduct tests of the processes and countermeasures contained in the Security Plan ("Security Tests") on an annual basis or as otherwise agreed by the Parties. The date, timing, content and conduct of such Security Tests shall be agreed in advance with the Authority. 4.2 The Authority shall be entitled to send a representative to witness the conduct of the Security Tests. The Contractor shall provide the Authority with the results of such tests (in a form approved by the Authority in advance) as soon as practicable after completion of each Security Test. 4.3 Without prejudice to any other right of audit or access granted to the Authority pursuant to this Contract, the Authority shall be entitled at any time and without giving notice to the Contractor to carry out such tests (including penetration tests) as it may deem necessary in relation to the Security Plan and the Contractor's compliance with and implementation of the Security Plan. The Authority may notify the Contractor of the results of such tests after completion of each such test. Security Tests shall be designed and implemented so as to minimise the impact on the delivery Services. If such tests impact adversely on its ability to deliver the Services to the agreed Service Levels, the Contractor shall be granted relief against any resultant under-performance for the period of the tests. 4.4 Where any Security Test carried out pursuant to paragraphs 4.2 or 4.3 above reveals any actual or potential security failure or weaknesses, the Contractor shall promptly notify the Authority of any changes to the Security Plan (and the implementation thereof) which the Contractor proposes to make in order to correct such failure or weakness. Subject to the Authority's approval in accordance with paragraph 3.12, the Contractor shall implement such changes to the Security Plan in accordance with the timetable agreed with the Authority or, otherwise, as soon as reasonably possible. For the avoidance of doubt, where the change to the Security Plan to address a non-compliance with the Security Policy or security requirements, the change to the Security Plan shall be at no additional cost to the Authority. For the purposes of this paragraph 4, a weakness means a vulnerability in security and a potential security failure means a possible breach of the Security Plan or security requirements.

  • Inspection and Tests 3.8.1 The Procuring entity or its representative shall have the right to inspect and/or to test the goods to confirm their conformity to the Contract specifications. The Procuring entity shall notify the tenderer in writing in a timely manner, of the identity of any representatives retained for these purposes. 3.8.2 The inspections and tests may be conducted in the premises of the tenderer or its subcontractor(s), at point of delivery, and/or at the Goods’ final destination If conducted on the premises of the tenderer or its subcontractor(s), all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring entity. 3.8.3 Should any inspected or tested goods fail to conform to the Specifications, the Procuring entity may reject the equipment, and the tenderer shall either replace the rejected equipment or make alterations necessary to make specification requirements free of costs to the Procuring entity. 3.8.4 The Procuring entity’s right to inspect, test and where necessary, reject the goods after the Goods’ arrival shall in no way be limited or waived by reason of the equipment having previously been inspected, tested and passed by the Procuring entity or its representative prior to the equipment delivery. 3.8.5 Nothing in paragraph 3.8 shall in any way release the tenderer from any warranty or other obligations under this Contract.

  • Follow-up Testing An employee shall submit to unscheduled follow-up drug and/or alcohol testing if, within the previous 24-month period, the employee voluntarily disclosed drug or alcohol problems, entered into or completed a rehabilitation program for drug or alcohol abuse, failed or refused a preappointment drug test, or was disciplined for violating the provisions of this Agreement and Employer work rules. The Employer may require an employee who is subject to follow-up testing to submit to no more than six unscheduled drug or alcohol tests within any 12 month period.

  • Inspections and Tests 26.1 The Supplier shall at its own expense and at no cost to the Procuring Entity carry out all such tests and/or inspections of the Goods and Related Services as are specified in the SCC. 26.2 The inspections and tests may be conducted on the premises of the Supplier or its Subcontractor, at point of delivery, and/or at the Goods' final destination, or in another place in Kenya as specified in the SCC. Subject to GCC Sub-Clause 26.3, if conducted on the premises of the Supplier or its Subcontractor, all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring Entity. 26.3 The Procuring Entity or its designated representative shall be entitled to attend the tests and/or inspections referred to in GCC Sub-Clause 26.2, provided that the Procuring Entity bear all of its own costs and expenses incurred in connection with such attendance including, but not limited to, all travelling and board and lodging expenses. 26.4 Whenever the Supplier is ready to carry out any such test and inspection, it shall give a reasonable advance notice, including the place and time, to the Procuring Entity. The Supplier shall obtain from any relevant third party or manufacturer any necessary permission or consent to enable the Procuring Entity or its designated representative to attend the test and/or inspection. 26.5 The Procuring Entity may require the Supplier to carry out any test and/or inspection not required by the Contract but deemed necessary to verify that the characteristics and performance of the Goods comply with the technical specifications codes and standards under the Contract, provided that the Supplier's reasonable costs and expenses incurred in the carrying out of such test and/or inspection shall be added to the Contract Price. Further, if such test and/or inspection impedes the progress of manufacturing and/or the Supplier's performance of its other obligations under the Contract, due allowance will be made in respect of the Delivery Dates and Completion Dates and the other obligations so affected. 26.6 The Supplier shall provide the Procuring Entity with a report of the results of any such test and/or inspection. 26.7 The Procuring Entity may reject any Goods or any part thereof that fail to pass any test and/or inspection or do not conform to the specifications. The Supplier shall either rectify or replace such rejected Goods or parts thereof or make alterations necessary to meet the specifications at no cost to the Procuring Entity, and shall repeat the test and/or inspection, at no cost to the Procuring Entity, upon giving a notice pursuant to GCC Sub- Clause 26.4. 26.8 The Supplier agrees that neither the execution of a test and/or inspection of the Goods or any part thereof, nor the attendance by the Procuring Entity or its representative, nor the issue of any report pursuant to GCC Sub-Clause 26.6, shall release the Supplier from any warranties or other obligations under the Contract.

  • Stability Testing Patheon shall conduct stability testing on the Products in accordance with the protocols set out in the Specifications for the separate fees specified in Schedule C. Patheon shall not make any changes to these testing protocols without prior written approval from the Client. In the event that any batch of Products fails stability testing, Patheon and the Client shall jointly determine the proceedings and methods to be undertaken to investigate the causes of such failure, including which party shall bear the cost of such investigation, provided that Patheon shall not be liable for any such costs unless there has been a failure by it to provide the Manufacturing Services in accordance with the Specifications and cGMPs. Patheon will provide any and all data and results relating to the stability testing upon request by the Client.

Most Referenced Clauses

Most Referenced Definitions