Common use of Submittals Clause in Contracts

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleunreas approval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal t schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient timeand no longer than ten (10) calendar days from receipt, in unless the Architect’s professional judgment, to permit adequate reviewOwner is notified of the reasons for the delay and approves a longer time period.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness as to cause no delay in the Work, while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. 6.4.1 The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.transmitted by the

Submittals. The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate reviewxxxxxx.xxxxxx without causing delay in the Work or in the activities of the Owner, Contractor or separate contractors.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect shall review and approve or take other appropriate action upon the Contractor’s submittals such as Shop Drawings, Product Data and Samples for the purpose of checking for conformance with the Contract Documents. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review. The Architect shall have a minimum of ten (10) business days to review submittals.

Submittals. The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably delay or withhold approval approval. of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review and approve the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.with

Submittals. The Architect shall review the ContractorConstruction Manager’s Project submittal schedule. The Architect and Construction Manager shall review and revise as necessary the submittal schedule in order to adhere to the approved Project Schedule and shall not unreasonably delay or withhold approval Section 3.10 of the scheduleGeneral Conditions. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule, , shall discuss and review the schedule with the Owner and shall not unreasonably delay or withhold approval of the scheduleschedule upon approval of the Owner. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the ContractorConstruction Manager’s submittal schedule and shall not unreasonably condition, delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with such reasonable promptness as to cause no delay in the work or activities of the Owner, Contractor or separate contractors, while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold unreaso approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the acc approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while reaso allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review and approve the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the scheduleapproval. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness promptness, while allowing sufficient time, time in the Architect’s professional judgment, judgment to permit adequate review.

Submittals. The Architect shall review the Contractor’s submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.or by 10 business days from date or receipt, in the absence of good cause for extension to permit adequate review, in which case the submittals shall be reviewed with reasonable promptness taking into account such good cause.

Submittals. The Architect shall review the ContractorConstruction Manager’s Project submittal schedule and shall not unreasonably condition, delay or withhold approval of the schedule. The Architect’s action in reviewing submittals transmitted by the Construction Manager shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.

Submittals. The Architect shall review the Contractor’s 's submittal schedule and shall not unreasonably delay or withhold approval of the schedule. The Architect’s 's action in reviewing submittals shall be taken in accordance with the approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time, in the Architect’s 's professional judgment, to permit adequate review.