POSSESSION OF THE PROPERTY The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
POSSESSION OF PROPERTY Possession of the Property free and clear of all uses and encroachments, except the Permitted Exceptions, shall be delivered to Purchaser at closing.
POSSESSION OF THE PLOT 7.1 Schedule for possession of the said Plot - The Promoter agrees and understands that timely delivery of possession of the Plot to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Plot along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Plot, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
POSSESSION OF THE APARTMENT 7.1 Schedule for possession of the said Apartment - The Promoter agrees and understands that timely delivery of possession of the Apartment to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Apartment along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Proceeding Affecting Xxxxxx’s Interest in the Property Borrower will be in Default if any action or proceeding begins, whether civil or criminal, that, in Xxxxxx’s judgment, could result in forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower can cure such a Default and, if acceleration has occurred, reinstate as provided in Section 20, by causing the action or proceeding to be dismissed with a ruling that, in Xxxxxx’s judgment, precludes forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower is unconditionally assigning to Lender the proceeds of any award or claim for damages that are attributable to the impairment of Xxxxxx’s interest in the Property, which proceeds will be paid to Lender. All Miscellaneous Proceeds that are not applied to restoration or repair of the Property will be applied in the order that Partial Payments are applied in Section 2(b).
Peaceful Possession The Authority hereby warrants that:
Inspection of Property The Borrower and each of its Subsidiaries will keep proper books and records in accordance with GAAP and will permit reasonable examinations of its books and records and reasonable inspections of its property (subject to reasonable procedures relating to safety and security), accompanied by personnel of the Borrower, by the Administrative Agent and any Lender and/or their respective accountants or other professional advisers; provided that such examinations and inspections (a) will occur not more frequently than once in any calendar year, with reasonable efforts to make combined visits (unless a Default or an Event of Default has occurred and is continuing in which case such examinations may occur as frequently as reasonably determined by the Administrative Agent or any Lender, with no obligation to combine visits), (b) will be at the sole expense of the Administrative Agent and/or requesting Lender, as the case may be (unless a Default or an Event of Default has occurred and is continuing in which case such examinations will be at the expense of the Borrower), (c) will be undertaken at reasonable times following the provision of written notice in advance to the Borrower, and (d) will not unduly interfere with the operations or management of the Borrower’s business. Notwithstanding anything set forth herein to the contrary, under no circumstances shall the Borrower or any Subsidiary be required to disclose, permit the inspection, examination or making copies or abstracts of, or discussion of, any document, information or other matter (i) that constitutes non−financial trade secrets or non-financial confidential proprietary information, (ii) in respect of which disclosure to the Administrative Agent or any Lender (or their respective Affiliates, representatives, contractors, accountants or other professionals) is prohibited by any Governmental Rule or binding confidentiality agreement with a Person that is not an Affiliate of the Borrower and that was not entered into in contemplation of this Agreement, (iii) that is subject to attorney−client or similar privilege or constitutes attorney work product, or (iv) in the case of any discussions with accountants, only if the Borrower has been given the opportunity to participate in the discussions.
Possession and Occupancy The Seller will deliver possession and occupancy of the Property to the Buyer at Closing. The Seller shall provide access to all locks, including keys, remote controls, and any security/access codes, necessary to operate all locks, mailboxes, and security systems.
