Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.
Tenant’s Work After the Commencement Date, Tenant at its sole cost and expense intends to construct leasehold improvements in the Demised Premises (“Tenant’s Work”) as detailed in the plans and specifications to be prepared by Tenant’s architect (“TI Architect”). Tenant shall be allowed to select a general contractor to perform the Tenant’s Work, provided said general contractor shall be properly licensed, bonded and of a reputation reasonably acceptable to Landlord. An affiliate of Landlord, Minkoff Development Corporation (“MDC”), shall act as Landlord’s construction manager to review plans and oversee construction of the Tenant’s Work by the general contractor. MDC shall receive a fee equal to one percent (1%) of the cost of the Tenant’s Work, which fee shall not exceed $50,000. Tenant shall have the right to submit plans for the Tenant’s Work in stages for portions of the Demised Premises. Tenant shall cause the TI Architect to prepare and deliver to Landlord for Landlord’s or MDC’s review preliminary plans (architectural, mechanical, electrical, plumbing and structural, if necessary) and specifications for the proposed leasehold improvements (the “Preliminary Plans”). Landlord shall have five (5) business days after its receipt thereof (or such additional time as may reasonably be necessary) to review the Preliminary Plans, request any changes it deems reasonably appropriate, and indicate on the Preliminary Plans which portions of the leasehold improvements are to be removed by Tenant prior to the expiration or termination of the Lease. The TI Architect shall modify the Preliminary Plans to accommodate Landlord’s changes, and resubmit the revised plans (the “Revised Preliminary Plans”) to Landlord for approval. If Tenant or the TI Architect elect not to make said changes to the Preliminary Plans, then Landlord shall have the right to require Tenant to perform corresponding restoration work to effect said changes prior to the expiration or termination of the Lease. Upon receipt of Landlord’s approval of the Revised Preliminary Plans, the TI Architect shall prepare a complete set of construction drawings and specifications for the construction of the proposed leasehold improvements (the “Working Drawings”). The Working Drawings shall be in sufficient detail for (i) Tenant’s general contractor to obtain bids from all trades for and to perform the work described on the Working Drawings; (ii) Tenant’s general contractor to secure building permits from the requisite governmental authorities having jurisdiction over same; and (iii) Landlord or MDC to indicate the portion of Tenant’s Work, if any, which Tenant is to remove by expiration or termination of the Lease. The Working Drawings shall conform to and be consistent with the Revised Preliminary Plans and comply with all applicable Laws and Insurance Requirements, as those terms are defined in the Lease. The Working Drawings shall be submitted to MDC for review and approval, which approval (or a request for changes to be made) shall be given within ten (10) days after receipt thereof. Within five (5) business days after MDC’s approval of the Working Drawings, as modified by any revisions requested by MDC, Landlord and Tenant shall initial same to confirm their mutual approval thereof (the “Approved Working Drawings ”). The Approved Working Drawings will indicate which portions of the Tenant’s Work, if any, will have to be removed by Tenant prior to the expiration or termination of the Lease, and Tenant will timely comply with such requirement and repair any damage to the Land or the Building caused thereby at its own expense. Tenant will have no obligation to remove any other portion of the Tenant’s Work.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:
Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted
Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount equal to the amount charged by any construction manager retained by Landlord (the "Construction Manager") up to a maximum of $6,121,750 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building (and Tenant's architect fees), and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Notwithstanding the foregoing, the Tenant Improvement Allowance shall not be used for (and Tenant shall have no responsibility for) the following costs except to the extent any of the foregoing are caused by Tenant, are due to Tenant Delays or result from the failure of Tenant to comply with the terms of the Lease or this Work Letter: (1) Property Maintenance Costs prior to the Delivery Date; (2) charges for overtime, except to the extent approved by Tenant; (3) costs to correct construction defects; (4) costs incurred to enforce contracts or cure contractor or subcontractor defaults (including legal fees); or (5) principal or interest on construction loan obtained by Landlord for construction of the Tenant Improvements.
Landlord Work All of the work described to be performed by Landlord in this paragraph 1 is collectively referred to as the "Landlord Work". All Landlord Work shall be performed in accordance with all applicable laws and this Lease, in a good and workmanlike manner, as appropriate by engineers, surveyors, architects and consultants, who are bondable, licensed in the State and of good reputation. Landlord's general contractor shall be experienced in shopping center development and in coordinating construction schedules with major anchors and national retailers. In the event that Landlord defaults at any time in completion of any component of the Landlord Work and fails to correct such default such that an Event of Default occurs, Tenant shall have the right, but not the obligation, to perform at Landlord's sole cost and expense, all or any part of Landlord's Work. Tenant shall exercise this right by providing Landlord with written notice thereof, which notice shall reasonably detail those portions of the Landlord Work which Tenant elects to complete. Tenant may exercise the rights set forth in this paragraph 1(d) from time to time so long as Tenant provides Landlord notice specified herein (i) within a reasonable amount of time prior to the date upon which Landlord would otherwise commence that portion of the Landlord Work, or (ii) at such other time where it is feasible for Tenant to take over that portion of the Landlord Work from Landlord. In the event and to the extent that Tenant exercises its right hereunder, Landlord agrees to cooperate in good faith and provide Tenant with reasonable assistance so that Tenant can complete said portions of the Landlord Work. Landlord agrees to reimburse Tenant for any and all costs incurred by Tenant in connection with any portion of the Landlord Work which Tenant is in the process of completing within fifteen (15) days after receipt of written request from Tenant, which request shall be reasonably supported by invoices and/or written description of the Landlord Work performed. In the event that the Landlord does not timely reimburse Tenant as hereinabove contemplated, Tenant shall be entitled to deduct the costs of such Landlord Work from rentals and other payments due under the Lease, together with interest at the Default Rate from the date of expenditure by Tenant until paid or otherwise deducted in full.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
