Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 4 contracts
Samples: Lease Agreement (Ascend Wellness Holdings, LLC), Lease Agreement (Ascend Wellness Holdings, LLC), Lease Agreement (Innovative Industrial Properties Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ’s ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' ’ risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's ’s personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's ’s obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 3 contracts
Samples: Lease Agreement (Vireo Health International, Inc.), Lease Agreement (Innovative Industrial Properties Inc), Lease Agreement (Innovative Industrial Properties Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.119.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld, conditioned or delayed; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ’s ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' ’ risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's ’s personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To Notwithstanding the fullest extent permitted by lawforegoing, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not ’s right to repair and rebuild the Premises Building pursuant to this Section 2119.3 shall not apply if Tenant has assigned this Lease to a third party, Tenant shall be in breachother than an affiliate; provided, and however, Landlord shall have the right to retain all casualty insurance proceeds require such third party to repair and condemnation proceedsrebuild the Building in accordance with this Section 19.
Appears in 3 contracts
Samples: Lease Agreement (BioMed Realty Trust Inc), Lease Agreement (Human Genome Sciences Inc), Lease Agreement (BioMed Realty Trust Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destructiondestruction that are not otherwise covered by landlord’s insurance for the Buildings. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 2 contracts
Samples: Lease Agreement (Ascend Wellness Holdings, LLC), Lease Agreement (Ascend Wellness Holdings, LLC)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as following the completion of the Commencement DateConstruction Work (as defined in the Purchase Agreement), and in a manner that is consistent with the plans and specifications previously approved by Landlord, or such new plans and specifications reasonably approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises in accordance with and subject to the terms of this Lease at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) required under this Lease; and (l) comply with such other conditions as Landlord may reasonably require. In addition, in connection with any restoration, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destructiondestruction to the extent required for Tenant to recommence normal business operations in the Premises. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises to the extent required pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 2 contracts
Samples: Lease Agreement (Innovative Industrial Properties Inc), Purchase and Sale Agreement (Innovative Industrial Properties Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.119.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld, conditioned or delayed; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ’s ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' ’ risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's ’s personal property and any alterations installed by Tenant existing at the time of such damage or destruction. Notwithstanding the foregoing, Tenant’s right to repair and rebuild the Building pursuant to this Section 19.3 shall not apply if Tenant has assigned this Lease to a third party, other than an affiliate; provided, however, Landlord shall have the right to require such third party to repair and rebuild the Building in accordance with this Section 19.3. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's ’s obligations under this Section 21Article 19, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21Article 19, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 2 contracts
Samples: Lease Agreement (Human Genome Sciences Inc), Lease Agreement (BioMed Realty Trust Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destructiondestruction that are not otherwise covered by landlord’s insurance for the Building. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 2 contracts
Samples: Lease Agreement (Ascend Wellness Holdings, LLC), Lease Agreement (Ascend Wellness Holdings, LLC)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.120.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 2120, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 2120, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 2 contracts
Samples: Lease Agreement (Innovative Industrial Properties Inc), Lease Agreement (Innovative Industrial Properties Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.120.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ’s ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' ’ risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's ’s personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's ’s obligations under this Section 2120, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 2120, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 1 contract
Samples: Lease Agreement (Innovative Industrial Properties Inc)
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ’s ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' ’ risk insurance) and (l1) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's ’s personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's ’s obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 1 contract
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as immediately prior to the occurrence of the Commencement Datesuch damage or destruction, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 1 contract
Samples: Purchase and Sale Agreement
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild any damage or destruction of the Premises under Section 21.1, and the Lease is not otherwise terminated pursuant to Section 21.2, then Tenant shall (a) submit its plans to repair such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld; (b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof); (d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant's ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work; (g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the nature of builders' risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In addition, Tenant shall, at its expense, replace or fully repair all of Tenant's personal property and any alterations installed by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect, defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments, actions, investigations, proceedings and liabilities arising out of or in connection with Tenant's obligations under this Section 21, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements. In the event Tenant does not repair and rebuild the Premises pursuant to this Section 21, Tenant shall be in breach, and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.
Appears in 1 contract
Samples: Lease Agreement (Innovative Industrial Properties Inc)