Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Term and Termination of Engagement; Exclusivity The term of Xxxxxxxxxx’x exclusive engagement will begin on the date hereof and end six (6) months thereafter (the “Term”). Notwithstanding anything to the contrary contained herein, the Company agrees that the provisions relating to the payment of fees, reimbursement of expenses, right of first refusal, tail, indemnification and contribution, confidentiality, conflicts, independent contractor and waiver of the right to trial by jury will survive any termination or expiration of this Agreement. Notwithstanding anything to the contrary contained herein, the Company has the right to terminate the Agreement for cause in compliance with FINRA Rule 5110(g)(5)(B)(i). The exercise of such right of termination for cause eliminates the Company’s obligations with respect to the provisions relating to the tail fees and right of first refusal. Notwithstanding anything to the contrary contained in this Agreement, in the event that an Offering pursuant to this Agreement shall not be carried out for any reason whatsoever during the Term, the Company shall be obligated to pay to Xxxxxxxxxx its actual and accountable out-of-pocket expenses related to an Offering (including the fees and disbursements of Xxxxxxxxxx’x legal counsel) and, if applicable, for electronic road show service used in connection with an Offering. During Xxxxxxxxxx’x engagement hereunder: (i) the Company will not, and will not permit its representatives to, other than in coordination with Xxxxxxxxxx, contact or solicit institutions, corporations or other entities or individuals as potential purchasers of the Securities and (ii) the Company will not pursue any financing transaction which would be in lieu of an Offering. Furthermore, the Company agrees that during Xxxxxxxxxx’x engagement hereunder, all inquiries from prospective investors will be referred to Xxxxxxxxxx. Additionally, except as set forth hereunder, the Company represents, warrants and covenants that no brokerage or finder’s fees or commissions are or will be payable by the Company or any subsidiary of the Company to any broker, financial advisor or consultant, finder, placement agent, investment banker, bank or other third-party with respect to any Offering.
License Term and Termination Unless otherwise specified, any license granted is perpetual, provided however that if Customer fails to comply with the terms of this Agreement, HP may terminate the license upon written notice. Immediately upon termination, or in the case of a limited-term license, upon expiration, Customer will either destroy all copies of the software or return them to HP, except that Customer may retain one copy for archival purposes only.
Effective Date of Agreement; Termination This Agreement shall become effective when the parties hereto have executed and delivered this Agreement. The obligations of the several Underwriters hereunder shall be subject to termination in the absolute discretion of the Representative, if (1) since the time of execution of this Agreement or the earlier respective dates as of which information is given in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, there has been any change or any development involving a prospective change in the business, properties, management, financial condition or results of operations of the Company and its subsidiaries taken as a whole, the effect of which change or development is, in the sole judgment of the Representative, so material and adverse as to make it impractical or inadvisable to proceed with the public offering or the delivery of the Securities on the terms and in the manner contemplated in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, or (2) since the time of execution of this Agreement, there shall have occurred: (A) a suspension or material limitation in trading in securities generally on the NYSE, the American Stock Exchange or the NASDAQ Stock Market; (B) a suspension or material limitation in trading in the Company’s common stock on the NYSE; (C) a general moratorium on commercial banking activities declared by either federal or New York State authorities or a material disruption in commercial banking or securities settlement or clearance services in the United States; (D) an outbreak or escalation of hostilities or acts of terrorism involving the United States or a declaration by the United States of a national emergency or war; or (E) any other calamity or crisis or any change in financial, political or economic conditions in the United States or elsewhere, if the effect of any such event specified in clause (D) or (E), in your sole judgment, makes it impractical or inadvisable to proceed with the public offering or the delivery of the Securities on the terms and in the manner contemplated in the Registration Statement, the Pre-Pricing Prospectuses, the Prospectus and the Permitted Free Writing Prospectuses, if any, or (3) since the time of execution of this Agreement, there shall have occurred any downgrading, or any notice or announcement shall have been given or made of: (A) any intended or potential downgrading or (B) any watch, review or possible change that does not indicate an affirmation or improvement in the rating accorded any securities of or guaranteed by the Company or any Significant Subsidiary by any “nationally recognized statistical rating organization,” as that term is defined in Rule 436(g)(2) under the Act. If the Representative elects to terminate this Agreement as provided in this Section 7, the Company and each other Underwriter shall be notified promptly in writing. If the sale to the Underwriters of the Securities, as contemplated by this Agreement, is not carried out by the Underwriters for any reason permitted under this Agreement, or if such sale is not carried out because the Company shall be unable to comply with any of the terms of this Agreement, the Company shall not be under any obligation or liability under this Agreement (except to the extent provided in Sections 4(o), 5 and 9 hereof), and the Underwriters shall be under no obligation or liability to the Company under this Agreement (except to the extent provided in Section 9 hereof) or to one another hereunder.
License Termination Customer may terminate the license for an ICA Program at any time on one month's written notice to IBM. For ICA Program licenses that Customer acquired for a one-time charge, replacement licenses may be acquired for an upgrade charge, if available. When Customer obtains licenses for these replacement ICA Programs, Customer agrees to terminate the license of the replaced ICA Programs when charges become due, unless IBM specifies otherwise. IBM may terminate Customer’s license if Customer fails to comply with the license terms. If IBM does so, Customer’s authorization to use the ICA Program is also terminated.
Term of Agreement; Termination A. The term of this Agreement shall commence on the date hereof.
B. This Agreement shall terminate at the Effective Time of the Merger or the earlier of (i) at any time prior to consummation of the Merger by the written consent of the parties hereto and (ii) termination of the Merger Agreement in accordance with its terms. Upon such termination, no party shall have any further obligations or liabilities hereunder; provided, however, such termination shall not relieve any party from liability for any willful breach of this Agreement prior to such termination.
Termination by Licensor Without Notice Licensee shall be deemed to be in default under this Agreement, and all rights granted herein shall automatically terminate without notice to Licensee, if Licensee becomes insolvent or makes a general assignment for the benefit of creditors; or if a petition in bankruptcy is filed by Licensee or against Licensee and not opposed by Licensee within sixty (60) days of such filing; or if Licensee is adjudicated as bankrupt or insolvent; or if a bill xx equity or other proceeding for the appointment of a receiver of Licensee or other custodian for Licensee's business or assets if filed and consented to by Licensee; or if a receiver or other permanent or temporary custodian of Licensee's assets or property, or any part thereof, is appointed by any court of competent jurisdiction; or if proceedings for a composition with creditors under any state or federal law should be instituted by or against Licensee; or if a material final judgment remains unsatisfied or of record for thirty (30) days or longer (unless supersedeas bond is filed); or if Licensee is dissolved; or if a suit to foreclose any lien or mortgage against real or personal property used in the operation of Licensee's business, the loss of which would have a material adverse effect on Licensee, is instituted against Licensee and not dismissed within thirty (30) days; or if execution is levied against Licensee's business or property, the loss of which would have a material adverse effect on Licensee; or if real or personal property of Licensee used in its business, the loss of which would have a material adverse effect on Licensee, shall be sold after levy thereupon by any sheriff, marshal, or constable; or if Licensee at any time ceases to operate or otherwise abandons its business or otherwise forfeits the right to do or transact business in any market(s) in the Territory; or if Licensee loses any government license required to engage in the Business or otherwise forfeits the right to do or transact business in one or more market(s), in which event Licensee's rights under this Agreement shall automatically terminate.
Termination by Licensee Licensee, at its option, may terminate the Agreement by providing Licensor written notice of intent to terminate, which such termination effective will be ninety (90) days following receipt of such notice by Licensor.
Term, Termination and Suspension 18.1 This Agreement shall be effective from the Effective Date for the Term. The Service shall commence on the Commencement Date and continue until the Completion Date, whereupon this Agreement shall expire unless terminated earlier in accordance with its terms.
18.2 You shall not commence any additional service in the event of notification of termination of this Agreement, however, in the event that service is provided to us beyond the Completion Date, the terms and conditions of this Agreement shall continue on a day-to-day basis terminable without cause upon twenty-four (24) hours prior written notice by either party to the other.
18.3 Either party may terminate a Service or this Agreement, in part or in whole, during the Term upon prior written notice without cause in accordance with the termination notice period as set out in Schedule 1.
18.4 We may terminate this Agreement at any time based upon your default of your obligations under this Agreement. We, in our sole discretion, may provide you with a notice to cure (“Cure Notice”) the breach that would otherwise amount to a basis to terminate this Agreement as a result of your failure to fulfill your obligations hereunder. You shall respond to any such Cure Notice within a reasonable time or within such time as provided therein, and you shall either cure the specified breach or provide assurances to cure the same which we, in our sole discretion, deem adequate.
18.5 Either party may terminate this Agreement immediately, if the other party:
(a) commits an irremediable breach; or
(b) is subject to a change of control or chooses to discontinue its business; or
(c) if the other party has a lack of funding or becomes or is deemed insolvent; or
(d) if the other party’s performance is affected by a force majeure event which lasts seven (7) days or more.
18.6 In the event of termination of this Agreement, all Fees then due and payable shall be paid to you.
18.7 Upon expiry or termination of this Agreement, you shall return all Government property or information or you shall irretrievably delete, as commercially practicable as possible, all Confidential Information, stored in any way using any device or application and all matter derived from such sources which is in your possession, custody or power and provide a signed statement that you have fully complied with your obligations under this section, save for any back-up required by law or as required in accordance with your record retention policy.
18.8 Upon expiry or termination of this Agreement, you shall provide us with all such assistance as may be reasonably necessary in order to end the relationship in a manner which causes the least inconvenience to us including assisting with the transfer of Data.
18.9 We may temporarily suspend a Service hereunder and shall confirm such instruction in writing to you.
18.10 Upon any such suspension, we shall pay all Fees and Expenses up until the time of such suspension of a Service. If, following suspension of a Service, there is no resumption within six (6) months, this Agreement may be terminated by you, and us shall make a payment of all outstanding Fees and Expenses in accordance with this Agreement if such amounts are due.
18.11 We may issue a written order to resume the provision of the Service within six (6) months of suspension in accordance with the terms and conditions of this Agreement.
18.12 The rights arising under this termination section represent your sole remedy and excludes common law rights to terminate and claim damages for any Loss you may suffer under this Agreement.
Agreement Term and Termination This agreement will remain in effect until the expiration or termination of Customer’s Subscription, whichever is earliest. Customer may terminate this agreement at any time by contacting its Reseller. The expiration or termination of this agreement will only terminate Customer’s right to place new orders for additional Products under this agreement.
