Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
PAYMENTS TO EXECUTIVE UPON AN EVENT OF TERMINATION (a) Upon the occurrence of an Event of Termination (as herein defined) during EXECUTIVE's term of employment under this Agreement, the provisions of this Section shall apply. As used in this Agreement, an "Event of Termination" shall mean and include any one or more of the following: (i) the termination by the BANK of EXECUTIVE's full-time employment hereunder for any reason other than a Change in Control, as defined in Section 5(a) hereof; disability, as defined in Section 6(a) hereof; death; retirement, as defined in Section 7 hereof; or Termination for Cause, as defined in Section 8 hereof; (ii) EXECUTIVE's resignation from the BANK's employ, upon (A) unless consented to by EXECUTIVE, a material change in EXECUTIVE's function, duties, or responsibilities, which change would cause EXECUTIVE's position to become one of lesser responsibility, importance, or scope from the position and attributes thereof described in Sections 1 and 2, above (any such material change shall be deemed a continuing breach of this Agreement), (B) a relocation of EXECUTIVE's principal place of employment by more than 35 miles from its location at the effective date of this Agreement, or a material reduction in the benefits and perquisites to EXECUTIVE from those being provided as of the effective date of this Agreement, (C) the liquidation or dissolution of the BANK, or (D) any material breach of this Agreement by the BANK. Upon the occurrence of any event described in clauses (A), (B), (C) or (D), above, EXECUTIVE shall have the right to elect to terminate his employment under this Agreement by resignation upon not less than sixty (60) days prior written notice given within a reasonable period of time not to exceed, except in case of a continuing breach, four (4) calendar months after the event giving rise to said right to elect.
Annual Statement as to Compliance, Notice of Servicer Termination Event (a) To the extent required by Section 1123 of Regulation AB, the Servicer, shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer and each Rating Agency, on or before March 31 of each year (regardless of whether the Seller has ceased filing reports under the Exchange Act), beginning on March 31, 2012, an officer’s certificate signed by any Responsible Officer of the Servicer, dated as of December 31 of the previous calendar year, stating that (i) a review of the activities of the Servicer during the preceding calendar year (or such other period as shall have elapsed from the Closing Date to the date of the first such certificate) and of its performance under this Agreement has been made under such officer’s supervision, and (ii) to such officer’s knowledge, based on such review, the Servicer has fulfilled in all material respects all its obligations under this Agreement throughout such period, or, if there has been a failure to fulfill any such obligation in any material respect, identifying each such failure known to such officer and the nature and status of such failure.
(b) The Servicer shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer and each Rating Agency, promptly after having obtained knowledge thereof, but in no event later than two (2) Business Days thereafter, written notice in an officer’s certificate of any event which with the giving of notice or lapse of time, or both, would become a Servicer Termination Event under Section 9.1(a). The Seller or the Servicer shall deliver to the Trustee, the Owner Trustee, the Trust Collateral Agent, the Backup Servicer, the Servicer or the Seller (as applicable) and each Rating Agency promptly after having obtained knowledge thereof, but in no event later than two (2) Business Days thereafter, written notice in an officer’s certificate of any event which with the giving of notice or lapse of time, or both, would become a Servicer Termination Event under any other clause of Section 9.1.
(c) The Servicer will deliver to the Issuer, on or before March 31 of each year, beginning on March 31, 2012, a report regarding the Servicer’s assessment of compliance with certain minimum servicing criteria during the immediately preceding calendar year, as required under Rules 13a-18 and 15d-18 of the Exchange Act and Item 1122 of Regulation AB.
(d) To the extent required by Regulation AB, the Servicer will cause any affiliated servicer or any other party deemed to be participating in the servicing function pursuant to Item 1122 of Regulation AB to provide to the Issuer, on or before March 31 of each year, beginning on March 31, 2012, a report regarding such party’s assessment of compliance with certain minimum servicing criteria during the immediately preceding calendar year, as required under Rules 13a-18 and 15d-18 of the Exchange Act and Item 1122 of Regulation AB.
(e) Xxxxx Fargo Bank, National Association acknowledges, in its capacity as Backup Servicer and Trust Collateral Agent under this Agreement and in its capacity as Indenture Trustee under the Basic Documents, that to the extent it is deemed to be participating in the servicing function pursuant to Item 1122 of Regulation AB, it will take any action reasonably requested by the Servicer to ensure compliance with the requirements of Section 4.10(d) and Section 4.11(b) hereof and with Item 1122 of Regulation AB. Such required documentation will be delivered to the Servicer by March 15 of each calendar year.
Termination for Non-Appropriation of Funds Notwithstanding any other provision of this Contract, the County shall not be obligated for the Contractor’s performance hereunder or by any provision of this Contract during any of the County’s future fiscal years unless and until the County’s Board of Supervisors appropriates funds for this Contract in the County’s Budget for each such future fiscal year. In the event that funds are not appropriated for this Contract, then this Contract shall terminate as of June 30 of the last fiscal year for which funds were appropriated. The County shall notify the Contractor in writing of any such non-allocation of funds at the earliest possible date.
Term of Agreement; Termination A. The term of this Agreement shall commence on the date hereof.
B. This Agreement shall terminate at the Effective Time of the Merger or the earlier of (i) at any time prior to consummation of the Merger by the written consent of the parties hereto and (ii) termination of the Merger Agreement in accordance with its terms. Upon such termination, no party shall have any further obligations or liabilities hereunder; provided, however, such termination shall not relieve any party from liability for any willful breach of this Agreement prior to such termination.
Termination and Survival (a) This Agreement shall become effective as of the date of this Agreement.
(b) This Agreement may be terminated, without the payment of any penalty, by the Fund or the Adviser at any time, with or without notice.
(c) This Agreement shall automatically terminate in the event of (i) the termination by the Fund of the Investment Advisory Agreement; (ii) the board of trustees of the Fund makes a determination to dissolve or liquidate the Fund; or (iii) upon a quotation or listing of the Fund’s securities on a national securities exchange (including through an initial public offering) or a sale of all or substantially all of the Fund’s assets to, or a merger or other liquidity transaction with, an entity in which the Fund’s shareholders receive shares of a publicly-traded company which continues to be managed by the Adviser or an affiliate thereof.
(d) Sections 3 and 4 of this Agreement shall survive any termination of this Agreement. Notwithstanding anything to the contrary, Section 2 of this Agreement shall survive any termination of this Agreement with respect to any Expense Payments that have not been reimbursed by the Fund to the Adviser.
Payments to and Duties of Advisor Upon Termination (a) After the Termination Date, the Advisor shall not be entitled to compensation for further services hereunder but shall be entitled to receive from CPA: 17 the following:
(i) all unpaid reimbursements of Organization and Offering Expenses and of Operating Expenses payable to the Advisor;
(ii) all earned but unpaid Asset Management Fees payable to the Advisor prior to the Termination Date;
(iii) all earned but unpaid Acquisition Fees and interest thereon, in each case payable to the Advisor relating to the acquisition of any Property prior to the Termination Date;
(iv) all earned but unpaid Subordinated Disposition Fees and interest thereon, payable to the Advisor relating to the sale of any Investment prior to the Termination Date; and
(v) all earned but unpaid Property Management Fees and Loan Refinancing Fees, if any, payable to the Advisor or its Affiliates relating to the management of any property prior to the termination of this Agreement.
(b) Notwithstanding the foregoing, if this Agreement is terminated by the Company for Cause, or by the Advisor for other than Good Reason, the Advisor will not be entitled to receive the sums in Section 20(a) (ii) through (v).
(c) Any and all amounts payable to the Advisor pursuant to Section 20(a) that, irrespective of the termination, were payable on a current basis prior to the Termination Date either because they were not subordinated or all conditions to their payment had been satisfied, shall be paid within 90 days after the Termination Date. All other amounts shall be paid in a manner determined by the Board, but in no event on terms less favorable to the Advisor than those represented by a note (i) maturing upon the liquidation of CPA: 17 or the Operating Partnership or three years from the Termination Date, whichever is earlier, (ii) with no less than twelve equal quarterly installments and (iii) bearing a fair, competitive and commercially reasonable interest rate (the “Note”). The Note, if any, may be prepaid by the Operating Partnership at any time prior to maturity with accrued interest to the date of payment but without premium or penalty. Notwithstanding the foregoing, any amounts that relate to Investments (i) shall be an amount which provides compensation to the Advisor only for that portion of the holding period for the respective Investments during which the Advisor provided services to CPA: 17, (ii) shall not be due and payable until the Investment Asset to which such amount relates is sold or refinanced, and (iii) shall not bear interest until the Investment to which such amount relates is sold or refinanced. A portion of the amount shall be paid as each Investment owned by CPA: 17 on the Termination Date is sold. The portion of such amount payable upon each such sale shall be equal to (i) such amount multiplied by (ii) the percentage calculated by dividing the fair value (at the Termination Date) of the Investment sold by CPA: 17 divided by the total fair value (at the Termination Date) of all Investments owned by CPA: 17 on the Termination Date.
(d) The Advisor shall promptly upon termination.
(i) pay over to the Operating Partnership all money collected and held for the account of CPA: 17 pursuant to this Agreement, after deducting any accrued compensation and reimbursement for its expenses to which it is then entitled;
(ii) deliver to the Board a full accounting, including a statement showing all payments collected by it and a statement of all money held by it, covering the period following the date of the last accounting furnished to the Board;
(iii) deliver to the Board all assets, including Properties and Loans, and documents of CPA: 17 then in the custody of the Advisor; and
(iv) cooperate with CPA: 17 to provide an orderly management transition.
EFFECT OF OPTIONAL TERMINATION Upon the exercise of the option to terminate pursuant to Section 7.2, this Agreement shall terminate and be of no further force or effect; provided, however, that:
A. the Parties respective rights and obligations under this Agreement with respect to the Tax Year or Tax Years (as the case may be) through and including the Tax Year during which such notification is delivered to the District, shall not be impaired or modified as a result of such termination and shall survive such termination unless and until satisfied and discharged; and
B. the provisions of this Agreement regarding payments (including liquidated damages and tax payments), records and dispute resolution shall survive the termination or expiration of this Agreement.
Certification Regarding Termination of Contract for Non-Compliance (Tex Gov. Code 552.374)
Termination of Agreement; Survival (a) The Underwriters may terminate their obligations under this Agreement, by notice to the Depositor, at any time at or prior to the Closing Date (i) if there has been, since the date of this Agreement or since the respective dates as of which information is given in the Registration Statement and the Prospectus, any material adverse change in the condition, financial or otherwise, or in the earnings, business affairs or business prospects of the Depositor, Xxxxx Fargo Bank or any other Mortgage Loan Seller whether or not arising in the ordinary course of business, (ii) if there has occurred any outbreak of hostilities or escalation thereof or other calamity or crisis the effect of which is such as to make it, in the reasonable judgment of any Underwriter, impracticable or inadvisable to market the Registered Certificates or to enforce contracts for the sale of the Registered Certificates, (iii) if trading in any securities of the Depositor or of Xxxxx Fargo Bank has been suspended or limited by the Commission or the New York Stock Exchange, or if trading generally on the American Stock Exchange or the New York Stock Exchange or on the NASDAQ National Market or the over the counter market has been suspended or limited, or minimum or maximum prices for trading have been fixed, or maximum ranges for prices have been required, by any of said exchanges or by such system or by order of the Commission, the National Association of Securities Dealers, Inc. or any other governmental authority, (iv) if a banking moratorium has been declared by either federal or New York authorities, or (v) if a material disruption in securities settlement, payments or clearance services in the United States or other relevant jurisdiction shall have occurred and be continuing on the Closing Date, or the effect of which is such as to make it, in the reasonable judgment of such Underwriter, impractical to market the Registered Certificates or to enforce contracts for the sale of the Registered Certificates.
(b) If this Agreement is terminated pursuant to this Section 12, such termination shall be without liability of any party to any other party, except as provided in Section 11 or Section 12(c) hereof.
(c) The provisions of Section 5(e) hereof regarding the payment of costs and expenses and the provisions of Sections 8 and 9 hereof shall survive the termination of this Agreement, whether such termination is pursuant to this Section 12 or otherwise.
