Landlord’s Contribution Landlord shall contribute rent abatements up to the total amount of ONE HUNDRED FIFTY THOUSAND DOLLARS ($150,000.00) (“Landlord’s Contribution”) on account of the cost of refurbishing the Leased Premises including design and engineering costs. Landlord’s Contribution shall be available to Tenant only as follows:
(i) Tenant shall submit to Landlord a written request to utilize a portion of Landlord’s Contribution as an abatement of one or more monthly installments of Base Rent (as hereinafter defined) (each a “Contribution Request”); (ii) each Contribution Request shall include evidence reasonably satisfactory to Landlord that Tenant has actually paid to contractors and other relevant professionals an amount at least equal to the amount sought in the Contribution Request in connection with construction, design and or other service and materials directly related to and necessary in connection with the Expansion Project (“Refit Expenses”); (iii) unless a Contribution Request is disputed by Landlord within ten (10) days from receipt by Landlord, Tenant shall be entitled to abatement of Base Rent monthly installment(s) first payable not less than thirty (30) days from submission of such Contribution Request to Landlord; (iv) in addition to the foregoing: (A) Tenant shall be limited to no more than three (3) contribution requests per year; (B) each Contribution Request shall be in an amount not less than the lesser of the remaining unused portion of Landlord’s Contribution and the Base Rent payable for one (1) month and shall specify how Tenant intends to apply the Base Rent abatements to upcoming monthly installment(s) of Base Rent; and (C) monthly abatements of Base Rent shall be applied to whole months and Tenant shall have no right to a partial abatement of monthly Base Rent other than with respect to the last Contribution Request.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter;
2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage.
2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
2.2.1.6 Sales and use taxes;
2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and
2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
Rent Abatement Except for the negligence or willful act of Tenant or its agents, employees, contractors or invitees, if all or any part of the Premises are rendered untenantable by fire or other casualty and this Lease is not terminated, Monthly Base Rent and Rent Adjustments shall xxxxx for that part of the Premises which is untenantable on a per diem basis from the date of the casualty until Landlord has Substantially Completed the repair and restoration work in the Premises which it is required to perform, provided, that as a result of such casualty, Tenant does not occupy the portion of the Premises which is untenantable during such period.
Landlord Work Landlord shall, at Landlord’s sole cost and expense, concurrently with Tenant’s construction of the Tenant Improvements, remove the existing demising wall and construct a Building standard demising wall at the Expansion Premises, which shall include studs, acoustical insulation and dry wall ready for finish on the Tenant side only and any necessary penetrations, fire dampers and sound traps (collectively, the “Demising Wall”), which Demising Wall shall be adjacent to the Expansion Premises as set forth on Exhibit A to this Amendment (collectively, the “Landlord Work”). Tenant may not change or alter the Landlord Work. Landlord shall use commercially reasonable efforts to Substantially Complete the Landlord Work no later than forty-five (45) days after the Expansion Delivery Date. In addition, Landlord shall, at Landlord’s sole cost and expense, to the extent required in order to allow Tenant to obtain a certificate of occupancy, or its legal equivalent, for the Expansion Premises for general office use assuming a normal and customary office occupancy density, cause the Landlord Work and the Building Common Areas (including the Base Building restrooms on the seventh (7th) floor of the Building), to comply with applicable building codes and other governmental laws, ordinances and regulations related to handicap access, which were enacted and enforced as of the date of this Amendment. Because Landlord shall be constructing the Landlord Work concurrently with Tenant’s construction of the Tenant Improvements, there will be a certain “overlap” period pursuant to which both Landlord’s representatives, employees, vendors and contractors and Tenant’s representatives, employees, vendors and contractors may be present and performing work in a portion of the Premises. During any such “overlap” period(s) when both parties and/or their respective employees, vendors, contractors or consultants are concurrently performing work in, or accessing, any portion of the Premises, neither party shall unreasonably interfere with or delay the work of the other party and/or its contractors or consultants, and both parties shall mutually coordinate and cooperate with each other, and shall cause their respective employees, vendors, contractors, and consultants to work in harmony with and to mutually coordinate and cooperate with the other’s employees, vendors, contractors and consultants, respectively, to minimize any interference or delay by either party with respect to the other party’s work. In addition, Landlord shall, and shall cause the other Landlord Parties to, use commercially reasonable efforts to minimize any interference with Tenant’s operations in the Existing Premises. Landlord shall have no obligation to move any furniture or other personal property of Tenant in the performance of Landlord Work. Tenant hereby agrees that the construction of the Landlord Work shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of rent. Except as otherwise expressly provided in the Lease (including this Tenant Work Letter), Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Landlord Work, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Landlord Work or Landlord’s actions in connection with the Landlord Work, or for any inconvenience or annoyance occasioned by the Landlord Work or Landlord’s actions in connection with the Landlord Work.
Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
Tenant Improvement Allowance Commencing as of January 1, 2011, Tenant shall be entitled to use the “Tenant Improvement Allowance”, as defined in Section 2 of this Amendment, for the costs relating to the design and construction of Tenant’s improvements or which are otherwise “Tenant Improvement Allowance items,” as that term is defined in Section 2.2.1, below (collectively, the “Tenant Improvements”). In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter or otherwise in connection with Tenant’s construction of the Tenant Improvements or any Tenant Improvement Allowance Items, as defined below, in a total amount which exceeds the sum of the Tenant Improvement Allowance. All Tenant Improvements for which the Tenant Improvement Allowance has been made available shall be deemed Landlord’s property under the terms of the Lease; provided, however, Landlord may, by written notice to Tenant given concurrently with Landlord’s approval of the “Final Working Drawings”, as that term is defined in Section 3.3, below, require Tenant, prior to the end of the Lease Term or promptly following any earlier termination of this Lease, at Tenant’s expense, to remove any Tenant Improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to a Building standard general office condition; provided, however, that Landlord shall not require Tenant to remove upon termination or expiration of this Lease, or condition its approval upon Tenant’s agreement to remove upon termination or expiration of this Lease, any Tenant Improvements constructed pursuant to this Tenant Work Letter (including, without limitation, Larc improvements) which constitute standard, non-extraordinary improvements for ordinary office, laboratory and/or Larc uses in biotech facilities. Any portion of the Tenant Improvement Allowance that is not disbursed or allocated for disbursement by December 31, 2013, shall revert to Landlord and Tenant shall have no further rights with respect thereto.
Vacating Premises (i) If the Assuming Bank elects not to purchase any owned Bank Premises, the notice of such election in accordance with Section 4.6(a) shall specify the date upon which the Assuming Bank's occupancy of such premises shall terminate, which date shall not be later than ninety (90) days after the date of the Assuming Bank's notice not to exercise such option. The Assuming Bank promptly shall relinquish and release to the Receiver such premises and the Furniture and Equipment and Fixtures located thereon in the same condition as at Bank Closing, normal wear and tear excepted. By occupying any such premises after the expiration of such ninety (90)-day period, the Assuming Bank shall, at the Receiver's option, (x) be deemed to have agreed to purchase such Bank Premises, and to assume all leases, obligations and liabilities with respect to leased Furniture and Equipment and leased Fixtures located thereon and any ground lease with respect to the land on which such premises are located, and (y) be required to purchase all Furniture and Equipment and Fixtures owned by the Failed Bank and located on such premises as of Bank Closing.
(ii) If the Assuming Bank elects not to accept an assignment of the lease or sublease any leased Bank Premises, the notice of such election in accordance with Section 4.6(b) shall specify the date upon which the Assuming Bank's occupancy of such leased Bank Premises shall terminate, which date shall not be later than the date which is one hundred eighty (180) days after Bank Closing. Upon vacating such premises, the Assuming Bank shall relinquish and release to the Receiver such premises and the Fixtures and the Furniture and Equipment located thereon in the same condition as at Bank Closing, normal wear and tear excepted. By failing to provide notice of its intention to vacate such premises prior to the expiration of the option period specified in Section 4.6(b), or by occupying such premises after the one hundred eighty (180)- day period specified above in this paragraph (ii), the Assuming Bank shall, at the Receiver's option, (x) be deemed to have assumed all leases, obligations and liabilities with respect to such premises (including any ground lease with respect to the land on which premises are located), and leased Furniture and Equipment and leased Fixtures located thereon in accordance with this Section 4.6 (unless the Receiver previously repudiated any such lease), and (y) be required to purchase all Furniture and Equipment and Fixtures owned by the Failed Bank at Fair Market Value and located on such premises as of Bank Closing.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Improvement Allowance a. Landlord shall contribute the Improvement Allowance towards the Improvement Costs in accordance with the terms of this Section. All Improvement Costs incurred by Landlord shall be deducted from the Improvement Allowance, and applied by Landlord to pay the Improvement Costs, as such costs are incurred. The Improvement Allowance shall remain available to be used by Tenant through October 31, 2014 (the “Allowance Expiration Date”). Any portion of the Improvement Allowance remaining undisbursed after the Allowance Expiration Date shall be retained by Landlord and Tenant shall not be entitled to any payment, Rent reduction or offset for any unused part of the Improvement Allowance. In no event shall Landlord be obligated to expend more than the Improvement Allowance.
b. Prior to commencement of construction of any Initial Improvements, Landlord shall submit to Tenant a written estimate (the “Estimate”) of the Improvement Costs. The Estimate shall include “allowance(s),” defined as an estimate of cost for an item of work not sufficiently defined in the documents to allow a fixed price to be obtained by the general contractor for which the Improvement Costs are to be increased or decreased, respectively, by the precise amount that the actual cost of the allowance item is either in excess of or less than the amount of the allowance for that item. Tenant shall approve the Estimate in writing within five (5) business days of Tenant’s receipt thereof. If Tenant does not approve or disapprove the Estimate in writing within said period, Tenant shall be deemed to have approved the Estimate. Landlord shall be under no obligation to construct any of the Initial Improvements until Tenant has expressly approved the Estimate.
c. If based on the Estimate, the Improvement Costs will exceed the Improvement Allowance, then prior to commencement of construction of any Initial Improvements, Tenant shall pay to Landlord one hundred percent (100%) of such projected excess amount. Landlord shall keep Tenant reasonably informed with respect to construction progress of the Initial Improvements, the occupancy of the Premises by Tenant and costs thereof. Landlord shall submit to Tenant monthly progress statements illustrating the cost to date of constructing the Initial Improvements. The statements of costs submitted to Landlord by Landlord’s contractors shall be conclusive for purposes of determining the actual cost of the items described therein. The amounts payable by Tenant hereunder constitute Rent payable pursuant to the Lease, and the failure to timely pay same constitutes a Default by Tenant as if Tenant shall have failed to pay Rent. Within ten (10) days after submission by Landlord of the foregoing statement, Tenant shall pay Landlord the amount, as set forth in such notice, by which the Improvement Costs exceeds the Improvement Allowance plus any amount previously paid by Tenant to Landlord. Landlord shall not disburse the Improvement Allowance until after Landlord disburses funds paid by Tenant for excess costs and provided that the Improvement Allowance is estimated to be sufficient to pay all remaining costs. Landlord shall disburse first the funds paid by Tenant and then the Improvement Allowance directly to the general contractor and to suppliers and subcontractors as Landlord deems appropriate. As soon as reasonably practical upon completion of the Initial Improvements, Landlord shall prepare and submit to Tenant a statement showing, in reasonable detail an accounting for the Improvement Costs and the total amount payable hereunder by Landlord to Tenant or Tenant to Landlord. Within ten (10) days after submission by Landlord of the foregoing statement, Tenant shall pay Landlord the amount, as set forth in such notice, by which the Improvement Costs exceeded the Improvement Allowance and any funds previously paid by Tenant to Landlord. If the Improvement Costs are less than the Improvement Allowance and any funds previously paid by Tenant to Landlord, then the excess funds previously paid by Tenant to Landlord shall be used to offset Base Rent; and Tenant shall not be entitled to any payment, Rent reduction or offset for any unused part of the Improvement Allowance.
d. After the Improvement Allowance has been expended by Landlord, the principal amount of the Improvement Allowance, together with interest thereon calculated at the Default Rate, shall be amortized evenly over the Term, and so long as Tenant does not default in its monetary obligations under the Lease, and fail to cure such default within the applicable period of cure, if any, provided under this Lease, then the balance of the Improvement Allowance shall be reduced each month by the principal amount amortized each month, and upon Landlord’s receipt of the final payment of Rent due during the initial Term of this Lease, Tenant shall have no liability to Landlord for the repayment of any portion of the Improvement Allowance or the interest that accrued and was amortized over the initial Term of this Lease. In the event of an uncured Default by Tenant under this Lease, then in addition to all of Landlord’s other remedies available under this Lease, Tenant shalt also be liable to Landlord for the entire unreduced principal balance of the Improvement Allowance remaining as of the date of default, and interest on such balance shall accrue at the Default Rate.
Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease.
(b) The Construction Allowance must be used on Tenant Work performed within the Relocation Premises and the Total Construction Costs and may not be used to pay for furniture, fixtures or equipment or as rent abatement, HOWEVER, notwithstanding the foregoing, provided Tenant is not in Default, Tenant may use a portion of the Construction Allowance, not to exceed an amount equal to $35.00 per rentable square foot of the Relocation Premises, to pay for furniture, fixtures or equipment, moving costs, cabling costs, and other soft costs associated with the Relocation Premises. Should Tenant elect to use a portion of the Construction Allowance to pay for such soft costs, at Landlord’s request Tenant shall execute and deliver a letter to Landlord confirming the exact amount of the Construction Allowance used to pay for such soft costs. Should Tenant elect to use a portion of the Construction Allowance to pay for such costs, Tenant shall provide Landlord with a written request that includes copies of paid invoices or receipts for reimbursement of such costs, and Landlord shall reimburse Tenant for such amounts within 30 days of receipt of Tenant’s request. Tenant shall provide lien waivers as appropriate. No portion of the Construction Allowance may be used as a credit against Rent due under the Lease.
(c) The Construction Allowance must be used (i.e. work performed and invoices submitted to Landlord) by June 30, 2020, or the Construction Allowance shall be deemed forfeited with no further obligation by Landlord with respect thereto.
(d) If Landlord defaults in Landlord’s obligation to pay the Construction Allowance pursuant to Section 9 of this Exhibit B-1, or any portion thereof, within five (5) days after the date the same is due, then Tenant shall have the right to give Landlord a second written notice (“Offset Exercise Notice”) requesting payment of such unpaid amounts and notifying Landlord that Tenant intends to offset against rent if not paid. In the event that Landlord fails to contest in good faith or fully pay such amounts within ten (10) business days after such Offset Exercise Notice is received by Landlord, then provided no Default exists Tenant may withhold and offset such unpaid sums from and against 25% of Base Rent next due until paid.
