Third-Party Applications Oracle or third party providers may offer Third Party Applications. Except as expressly set forth in the Estimate/Order Form, Oracle does not warrant any such Third Party Applications, regardless of whether or not such Third Party Applications are provided by a third party that is a member of an Oracle partner program or otherwise designated by Oracle as “Built For NetSuite,” "certified," "approved" or “recommended.” Any procurement by Customer of such Third Party Applications or services is solely between Customer and the applicable third party provider. Customer may not use Third Party Applications to enter and/or submit transactions to be processed and/or stored in the Cloud Service, unless Customer has procured the applicable subscription to the Cloud Service for such use and access.
Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions: (i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim. (ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed. (iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.
Updated Information Submission by Interconnection Customer The updated information submission by the Interconnection Customer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. The Interconnection Customer shall submit a completed copy of the Electric Generating Unit data requirements contained in Appendix 1 to the LGIP. It shall also include any additional information provided to the Participating TO and the CAISO for the Interconnection Studies. Information in this submission shall be the most current Electric Generating Unit design or expected performance data. Information submitted for stability models shall be compatible with the Participating TO and CAISO standard models. If there is no compatible model, the Interconnection Customer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Third Party Approvals (a) Abraxas and Energy and their respective Subsidiaries, shall cooperate and use their respective reasonable best efforts to prepare all documentation, to effect all filings, to obtain all permits, consents, approvals and authorizations of all third parties and the expiration or termination of any waiting period under the HSR Act necessary to consummate the transactions contemplated by this Agreement and to comply with the terms and conditions of such permits, consents, approvals and authorizations and to cause the Merger to be consummated as expeditiously as practicable. (b) Each party hereto agrees that it will consult with the other parties hereto with respect to the obtaining of all material permits, consents, approvals, clearances and authorizations of all third parties and Governmental Authorities necessary or advisable to consummate the transactions contemplated by this Agreement, and each party will keep the other parties apprised of the status of material matters relating to completion of the transactions contemplated hereby. To the extent practicable and in each case subject to applicable Laws relating to the exchange of information, Abraxas and Energy agree to (i) cooperate and consult with each other, (ii) furnish to the other such necessary information and assistance as the other may reasonably request in connection with its preparation of any notifications or filings, (iii) keep each other apprised of the status of matters relating to the completion of the transactions contemplated thereby, including promptly furnishing the other with copies of notices or other communications received by such party from, or given by such party to, any third party and/or any Governmental Authority with respect to such transactions, (iv) permit the other party to review and incorporate the other party’s reasonable comments in any communication to be given by it to any Governmental Authority with respect to obtaining the necessary approvals for the Merger, and (v) not to participate in any meeting or discussion related to the transactions contemplated hereby, either in person or by telephone, with any Governmental Authority in connection with the proposed transactions unless, to the extent not prohibited by such Governmental Authority, it gives the other party the opportunity to attend and observe. In exercising the foregoing rights, each of the parties hereto agrees to act reasonably and promptly. (c) Each party agrees, upon request, to furnish the other party with all information concerning itself, its Subsidiaries, directors, officers and equityholders and such other matters as may be reasonably necessary or advisable in connection with the Proxy Statement or any filing, notice or application made by or on behalf of such other party or any of such Subsidiaries to any Governmental Authority in connection with the transactions contemplated hereby.
Claims Submission Unless otherwise prohibited by federal or state law, Provider will submit Clean Claims for all Covered Services to BCBSM within one hundred eighty (180) days of the date of service.
Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.
Updated Information Submission by Developer The updated information submission by the Developer, including manufacturer information, shall occur no later than one hundred eighty (180) Calendar Days prior to the Trial Operation. Developer shall submit a completed copy of the Large Generating Facility data requirements contained in Appendix 1 to the Large Facility Interconnection Procedures. It shall also include any additional information provided to Connecting Transmission Owner for the Interconnection Feasibility Study and Interconnection Facilities Study. Information in this submission shall be the most current Large Generating Facility design or expected performance data. Information submitted for stability models shall be compatible with NYISO standard models. If there is no compatible model, the Developer will work with a consultant mutually agreed to by the Parties to develop and supply a standard model and associated information. If the Developer’s data is different from what was originally provided to Connecting Transmission Owner and NYISO pursuant to an Interconnection Study Agreement among Connecting Transmission Owner, NYISO and Developer and this difference may be reasonably expected to affect the other Parties’ facilities or the New York State Transmission System, but does not require the submission of a new Interconnection Request, then NYISO will conduct appropriate studies to determine the impact on the New York State Transmission System based on the actual data submitted pursuant to this Article 24.3. Such studies will provide an estimate of any additional modifications to the New York State Transmission System, Connecting Transmission Owner’s Attachment Facilities, or System Upgrade Facilities or System Deliverability Upgrades based on the actual data and a good faith estimate of the costs thereof. The Developer shall not begin Trial Operation until such studies are completed. The Developer shall be responsible for the cost of any modifications required by the actual data, including the cost of any required studies.
Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.
Notice of Legal Matter or Litigation Grantee will send notice to the Substance Use Disorder (SUD) email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx of any litigation or legal matter related to or affecting this Contract within seven (7) calendar days of becoming aware of the litigation or legal matter.
