WARRANTY PROCEDURES You need proof of purchase for warranty service.
Safety Procedures The Contractor shall:
(a) comply with all applicable safety regulations according to Attachment H;
(b) take care for the safety of all persons entitled to be on the Site;
(c) use reasonable efforts to keep the Site and Works clear of unnecessary obstruction so as to avoid danger to these persons;
(d) provide fencing, lighting, guarding and watching of the Works until completion and taking over under clause 10 [Employer's Taking Over]; and
(e) provide any Temporary Works (including roadways, footways, guards and fences) which may be necessary, because of the execution of the Works, for the use and protection of the public and of owners and occupiers of adjacent land.
Reply Procedures In connection with any Auction, each Lender holding the relevant Term Loans subject to such Auction may, in its sole discretion, participate in such Auction and may provide the Auction Agent with a notice of participation (the “Return Bid”) which shall be in a form reasonably acceptable to the Auction Agent, and shall specify (i) a discount to par (that must be expressed as a price at which it is willing to sell all or any portion of such Term Loans) (the “Reply Price”), which (when expressed as a percentage of the par principal amount of such Term Loans) must be within the Discount Range and (ii) a principal amount of such Term Loans, which must be in whole increments of $1,000,000 (or, in any case, such lesser amount of such Term Loans of such Lender then outstanding or which is otherwise reasonably acceptable to the Auction Agent) (the “Reply Amount”). Lenders may only submit one Return Bid per Auction, but each Return Bid may contain up to three bids only one of which may result in a Qualifying Bid. In addition to the Return Bid, the participating Lender must execute and deliver, to be held in escrow by the Auction Agent, an Assignment and Assumption with the dollar amount of the Term Loans to be assigned to be left in blank, which amount shall be completed by the Auction Agent in accordance with the final determination of such Lender’s Qualifying Bid pursuant to clause (c) below. Any Lender whose Return Bid is not received by the Auction Agent by the Auction Response Date shall be deemed to have declined to participate in the relevant Auction with respect to all of its Term Loans.
Indemnity Procedures Promptly after receipt by an Indemnified Party of any claim or notice of the commencement of any action or administrative or legal proceeding or investigation as to which the indemnity provided for in Article 18.1 may apply, the Indemnified Party shall notify the Indemnifying Party of such fact. Any failure of or delay in such notification shall not affect a Party’s indemnification obligation unless such failure or delay is materially prejudicial to the Indemnifying Party. Except as stated below, the Indemnifying Party shall have the right to assume the defense thereof with counsel designated by such Indemnifying Party and reasonably satisfactory to the Indemnified Party. If the defendants in any such action include one or more Indemnified Parties and the Indemnifying Party and if the Indemnified Party reasonably concludes that there may be legal defenses available to it and/or other Indemnified Parties which are different from or additional to those available to the Indemnifying Party, the Indemnified Party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on its own behalf. In such instances, the Indemnifying Party shall only be required to pay the fees and expenses of one additional attorney to represent an Indemnified Party or Indemnified Parties having such differing or additional legal defenses. The Indemnified Party shall be entitled, at its expense, to participate in any such action, suit or proceeding, the defense of which has been assumed by the Indemnifying Party. Notwithstanding the foregoing, the Indemnifying Party (i) shall not be entitled to assume and control the defense of any such action, suit or proceedings if and to the extent that, in the opinion of the Indemnified Party and its counsel, such action, suit or proceeding involves the potential imposition of criminal liability on the Indemnified Party, or there exists a conflict or adversity of interest between the Indemnified Party and the Indemnifying Party, in such event the Indemnifying Party shall pay the reasonable expenses of the Indemnified Party, and (ii) shall not settle or consent to the entry of any judgment in any action, suit or proceeding without the consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed.
COMPLAINT PROCEDURES CONTRACTOR shall maintain and adhere to its written procedures for responding to parent complaints. These procedures shall include annually notifying and providing parents of LEA students with appropriate information (including complaint forms) for the following: (1) Uniform Complaint Procedures pursuant to Title 5 of the California Code of Regulations section 4600 et seq.; (2) Nondiscrimination policy pursuant to Title 5 of the California Code of Regulations section 4960 (a); (3) Sexual Harassment Policy, California Education Code 231.5 (a) (b) (c); (4) Title IX Pupil Grievance Procedure, Title IX 106.8 (a) (d) and 106.9 (a); and (5) Notice of Privacy Practices in compliance with Health Insurance Portability and Accountability Act (HIPAA), if applicable. CONTRACTOR shall include verification of these procedures to the LEA upon request. CONTRACTOR shall immediately notify LEA of any complaints filed against it related to LEA students and provide LEA with all documentation related to the complaints and/or its investigation of complaints, including any and all reports generated as a result of an investigation.
Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.
RECOVERY PROCEDURES The nature and severity of any disaster will influence the recovery procedures. One crucial factor in determining how BellSouth will proceed with restoration is whether or not BellSouth's equipment is incapacitated. Regardless of who's equipment is out of service, BellSouth will move as quickly as possible to aid with service recovery; however, the approach that will be taken may differ depending upon the location of the problem.
New Procedures New procedures as to who shall provide certain of these services in Section 1 may be established in writing from time to time by agreement between the Fund and the Transfer Agent. The Transfer Agent may at times perform only a portion of these services and the Fund or its agent may perform these services on the Fund's behalf;
Company Procedures Whenever required under this Section 5 to effect the Registration of any Registrable Securities, the Company shall use its commercially reasonable efforts to, as expeditiously as reasonably possible:
(a) prepare and file with the SEC a Registration Statement with respect to such Registrable Securities and use its commercially reasonable efforts to cause such Registration Statement to become effective and remain effective until all Registrable Securities covered by such Registration Statement have been sold or cease to be Registrable Securities;
(b) prepare and file with the SEC such amendments, post-effective amendments and supplements to such Registration Statement and the Prospectus used in connection with such Registration Statement as may be necessary to keep such Registration Statement effective and to comply with the provisions of the Securities Act with respect to the disposition of all securities covered by such Registration Statement in accordance with the intended methods of disposition by sellers thereof set forth in such Registration Statement;
(c) in the event of any Underwritten Offering, enter into and perform its obligations under an underwriting agreement, in usual and customary form, with the Managing Underwriter(s) of such offering; the Purchaser and any other parties participating in such underwriting shall also enter into and perform its obligations under such an agreement;
(d) notify the Purchaser as soon as reasonably possible after notice thereof is received by the Company of any written comments by the SEC or any request by the SEC or any other federal or state Governmental Entity for amendments or supplements to such Registration Statement or such Prospectus or for additional information;
(e) notify the Purchaser at any time when a Prospectus relating thereto is required to be delivered under the Securities Act, of the happening of any event as a result of which the Prospectus included in such Registration Statement, as then in effect, includes a material misstatement or omission;
(f) notify the Purchaser as soon as reasonably practicable after notice thereof is received by the Company of the issuance by the SEC of any stop order suspending the effectiveness of such Registration Statement or any order by the SEC or any other regulatory authority preventing or suspending the use of any preliminary or final Prospectus or the initiation or threatening of any proceedings for such purposes, or any notification with respect to the suspension of the qualification of the Equity Securities for offering or sale in any jurisdiction or the initiation or threatening of any proceeding for such purpose;
(g) use its commercially reasonable efforts to prevent the issuance of any stop order suspending the effectiveness of any Registration Statement or of any order preventing or suspending the use of any preliminary or final Prospectus and, if any such order is issued, to obtain the withdrawal of any such order as soon as practicable;
(h) in the case of an Underwritten Offering, make available for inspection by the Underwriter participating in any distribution pursuant to such Registration, and any attorney, accountant or other agent retained by the Underwriter, all financial and other records, pertinent corporate documents and properties of the Company, as such parties may reasonably request, and cause the Company’s officers, directors and employees to supply all information reasonably requested by the Underwriter, attorney, accountant or agent in connection with such Registration Statement;
(i) use its commercially reasonable efforts to register or qualify, and cooperate with the Underwriters, if any, and their respective counsel, in connection with the Registration or qualification of such Equity Securities for offer and sale under the “Blue Sky” or securities laws of each state and other jurisdiction of the United States as the Underwriters, if any, or their respective counsel reasonably request in writing, and do any and all other things reasonably necessary or advisable to keep such Registration or qualification in effect; provided that the Company shall not be required to qualify generally to do business in any jurisdiction where it is not then so qualified or take any action which would subject it to taxation or service of process in any such jurisdiction where it is not then so subject;
(j) in the case of an Underwritten Offering, obtain for delivery to the Underwriters an opinion or opinions from counsel for the Company, dated the date of the closing under the underwriting agreement, in customary form, scope and substance, which opinions shall be reasonably satisfactory to the Underwriters, as the case may be, and their counsel;
(k) in the case of an Underwritten Offering, obtain for delivery to the Underwriters, a cold comfort letter from the Company’s independent certified public accountants in customary form and covering such matters of the type customarily covered by cold comfort letters as the Managing Underwriter or Underwriters reasonably request, dated the date of execution of the underwriting agreement and brought down to the closing under the underwriting agreement;
(l) use its commercially reasonable efforts to list the Registrable Securities that are covered by such Registration Statement with any securities exchange or automated quotation system on which the Common Stock of the Company is then listed;
(m) provide and cause to be maintained a transfer agent and registrar for all Registrable Securities covered by the applicable Registration Statement from and after a date not later than the effective date of such Registration Statement;
(n) in the case of an Underwritten Offering that is marketed, cause the senior executive officers of the Company to participate in the customary “road show” presentations that may be reasonably requested by the Underwriters and otherwise to facilitate, cooperate with and participate in each proposed offering contemplated herein and customary selling efforts related thereto; and
(o) otherwise, in good faith, reasonably cooperate with, and take such customary actions as may reasonably be requested by, the Purchaser, in connection with such Registration.
Claim Procedures Claim forms or claim information as to the subject policy can be obtained by contacting Benmark, Inc. (800-544-6079). When the Named Fiduciary has a claim which may be covered under the provisions described in the insurance policy, they should contact the office named above, and they will either complete a claim form and forward it to an authorized representative of the Insurer or advise the named Fiduciary what further requirements are necessary. The Insurer will evaluate and make a decision as to payment. If the claim is payable, a benefit check will be issued in accordance with the terms of this Agreement. In the event that a claim is not eligible under the policy, the Insurer will notify the Named Fiduciary of the denial pursuant to the requirements under the terms of the policy. If the Named Fiduciary is dissatisfied with the denial of the claim and wishes to contest such claim denial, they should contact the office named above and they will assist in making an inquiry to the Insurer. All objections to the Insurer's actions should be in writing and submitted to the office named above for transmittal to the Insurer.
