TIME OF COMPLETION. This project’s start date is scheduled for November 20, 2020, and completion date is May 28, 2021. The Contractor agrees to proceed with the work expeditiously without any delay or cessation, except such as may reasonably be beyond his control, and to employ a force of workmen sufficient so to perform the work covered by this Contract in such manner as to expedite the work of such other Contractors as may be engaged upon the work, as further provided in the Instructions to Bidders, to the end that the work to be performed by the Contractor shall be fully completed on or before the 28th day of May, 2021, subject to such adjustment of said date as may be made in accordance with this Contract. It is specifically agreed that the Contractor shall be bounden for damages, as hereinafter provided, for each and every day's delay which may be due or traceable to the Contract. In case the Contractor shall fail to perform fully the Contract within the agreed time limit, he shall pay to the City of Milwaukee, as liquidated damages for such default, the sum of $250.00 per day for each and every day's delay in completing the performance thereof after such time limit.
TIME OF COMPLETION. The Owner shall issue a Notice to Proceed identifying the date for commencement of the Work. The commencement date shall be 10 or more days after the date the notice is issued. The Contractor shall achieve substantial completion of the Work within _____________________ (____) calendar days after the commencement date, as such completion date may be extended by approved Change Orders. The time set forth for completion of the Work is an essential element of the Contract.
TIME OF COMPLETION. The work to be performed under this Contract shall be commenced on the date set forth in the Notice to Proceed and shall be completed on or before August 1, 2024. The Contractor agrees that Owner may retain from the monies due the Contractor the actual value of the damages to the Owner as a direct result of the Contractor’s delay or not completing the project in the required time allowance plus approved time extensions.
TIME OF COMPLETION. The Contractor agrees to Substantially Complete the Project within calendar days from the date of the Notice to Proceed, in addition, the Contractor agrees to finally complete the Project from Substantial Completion to Final Acceptance within calendar days for a total time of completion of the entire Project of calendar days. The Contractor shall perform the Work with due diligence to completion.
TIME OF COMPLETION. Contractor agrees to complete all work as described in this Contract within one hundred twenty (120) calendar days from the date of the Owner’s Notice to Proceed free of all liens, claims and demands of any kind for materials, equipment, supplies, services, labor, taxes and damages to property or persons, in the manner and under the conditions specified within the time or times specified in this Contract.
TIME OF COMPLETION. 18.1 ONCE THE DISTRICT HAS ISSUED A NOTICE TO PROCEED, CONTRACTOR SHALL PROCEED WITH THE CONSTRUCTION OF THE PROJECT WITH REASONABLE DILIGENCE. XXXXXXXXXX AGREES THAT THE PROJECT WILL BE SUBSTANTIALLY COMPLETE WITHIN THE CALENDAR DAYS DESIGNATED IN ARTICLE 3 FROM THE NOTICE TO PROCEED. SAID CONTRACT TIME MAY BE EXTENDED FOR SUCH PERIODS OF TIME AS ALLOWED UNDER THE CONTRACT DOCUMENTS. IF THE PROJECT IS NOT SUBSTANTIALLY COMPLETED IN ACCORDANCE WITH THE FOREGOING, IT IS UNDERSTOOD THAT THE DISTRICT WILL SUFFER DAMAGE SINCE CONTRACTOR HAS OVERSTAYED ITS LEASE TERM. IT BEING IMPRACTICAL AND INFEASIBLE TO DETERMINE THE AMOUNT OF ACTUAL DAMAGE, IT IS AGREED THAT CONTRACTOR’S EXTENSION OF THE LEASE SHALL RESULT IN LIQUIDATED DAMAGES, AND NOT AS A PENALTY, THE SUM SET FORTH IN ARTICLE 3 FOR EACH CALENDAR DAY OF DELAY UNTIL WORK IS SUBSTANTIALLY COMPLETED. CONTRACTOR AND ITS SURETY SHALL BE LIABLE FOR THE AMOUNT THEREOF. ANY MONEY DUE OR TO BECOME DUE THE CONTRACTOR MAY BE RETAINED BY THE DISTRICT TO COVER SAID LIQUIDATED DAMAGES FOR OVERSTAYING THE LEASE. SHOULD SUCH MONEY NOT BE SUFFICIENT TO COVER SAID LIQUIDATED DAMAGES, THE DISTRICT SHALL HAVE THE RIGHT TO RECOVER THE BALANCE FROM THE CONTRACTOR OR ITS SURETIES, WHO WILL PAY SAID BALANCE FORTHWITH.
TIME OF COMPLETION. 6.01 Xxxxxx agrees that the Work will be substantially complete and will be completed and ready for final payment in accordance with Paragraph 15.06 of the General Conditions on or before the dates or within the number of calendar days indicated in the Agreement.
TIME OF COMPLETION. In the event of the failure of the Consultant to complete the work within the time specified solely due to their own cause of delay, the Consultant may be liable to the Owner for all direct and consequential losses or damages that the Owner may incur because of the delay; such as, but not limited to, added costs of the project and the cost of furnishing temporary services and facilities, if any. Any such sums for which the Consultant is liable may be deducted by the Owner from any monies due or to become due to the Consultant.
TIME OF COMPLETION. The prompt completion of the Work under the Scope of Work relates is critical to the City. Unnecessary delays in providing Work under a Scope of Work shall be grounds for dismissal of the Contractor and termination of this Agreement without any or further liability to the City other than a prorated payment for necessary, timely, and conforming work done by Contractor prior to the time of termination.
TIME OF COMPLETION. The Contractor further covenants and agrees that all of the said materials shall be furnished and delivered and all of the said labor shall be done and performed in every respect to the satisfaction and approval of the State Engineer and that the said work shall be turned over to the State Engineer, complete and ready for use, on or before the specified time herein. The work shall be free and discharged of all claims and demands whatsoever for, or on account of any and all labor and materials used or furnished to be used in said work. It is expressly understood and agreed that in case of failure on the part of the Contractor, for any reason, except with the written consent of the State Engineer, to complete the entire work to the satisfaction of the State Engineer, and within the aforesaid time limit, the party of the first part shall deduct from any money due, or which may become due the Contractor, as liquidated damages, an amount in accordance with Subsection 108.09 of the Contract Specifications. If no money shall be due the Contractor, the State shall have a cause of action to recover against the Contractor in a court of competent jurisdiction, liquidated damages, in accordance with Subsection 108.09 of the Contract Specifications, said deduction to be made, or said sum to be recovered, not as a penalty, but as liquidated damages; provided, however, that upon receipt of written notice from the Contractor, of the existence of causes, as herein provided, over which said Contractor has no control and which must delay the completion of said work or any delay occasioned by the Arizona Department of Transportation, the State Engineer may extend the period hereinbefore specified for the completion of said work in accordance with the Specifications and in such case, the Contractor shall become liable for said liquidated damages for delays commencing from date said extension period shall expire. After the date as set up in Contract plus any extension granted, no further payments shall be made the Contractor until all work is completed and accepted by the State engineer. It is also agreed that the date of completion shall be that upon which the work is accepted by the State Engineer.
