Failure of Allottee to take Possession of Apartment Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the Apartment to the allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2.
Failure of Allottee to take Possession of [Apartment/Plot] Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the [Apartment/Plot] from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the [Apartment/Plot] to the allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2.
Failure of Allottee to take Possession of plot [Apartment/Plot] - Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the plot [Apartment/Plot] from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the plot [Apartment/Plot] to the allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2. Also in the event of Allottee’s failure to take possession or getting conveyance deed done in time limit, for any reason whatsoever, expenditure incurred on the taking care and/or maintenance of the plot shall be charged extra at the rate of rupees thirty per sqm of the plot area plus taxes per month from the date onwards other than external maintenance charges, and be paid by the purchaser as and when demanded by the builder.
Failure of Allottee to take Possession of [Apartment/Plot] - Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the [Apartment/Plot] from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the [Apartment/Plot] to the allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2.
POSSESSION OF THE PROPERTY The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on .
Proceeding Affecting Xxxxxx’s Interest in the Property Borrower will be in Default if any action or proceeding begins, whether civil or criminal, that, in Xxxxxx’s judgment, could result in forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower can cure such a Default and, if acceleration has occurred, reinstate as provided in Section 20, by causing the action or proceeding to be dismissed with a ruling that, in Xxxxxx’s judgment, precludes forfeiture of the Property or other material impairment of Xxxxxx’s interest in the Property or rights under this Security Instrument. Borrower is unconditionally assigning to Lender the proceeds of any award or claim for damages that are attributable to the impairment of Xxxxxx’s interest in the Property, which proceeds will be paid to Lender. All Miscellaneous Proceeds that are not applied to restoration or repair of the Property will be applied in the order that Partial Payments are applied in Section 2(b).
POSSESSION OF THE PLOT 7.1 Schedule for possession of the said Plot - The Promoter agrees and understands that timely delivery of possession of the Plot to the allottee’s and the common areas to the association of allottee’s or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the Plot along with ready and complete common areas with all specifications, amenities and facilities of the project in place on (Date) unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee’s agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Plot, provided that such Force Majeure conditions are not of a nature, which make it impossible for the contract to be implemented. The Allottee’s agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee’s the entire amount received by the Promoter from the allotment within 45 days from that date. The promoter shall intimate the allottee’s about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee’s, the Allottee’s agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Failure of Allottee to take Possession of Plot Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Plot from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement, and the Promoter shall give possession of the Plot to the allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2.
Conditions When the Government May Obtain Title Upon DARPA’s written request, the Performer shall convey title to any Subject Invention to DARPA under any of the following conditions:
Purchase by Receiver The Receiver shall purchase Assets that are specified in the Put Notice and shall assume Related Liabilities with respect to such Assets, and the transfer of such Assets and Related Liabilities shall be effective as of a date determined by the Receiver which date shall not be later than thirty (30) days after receipt by the Receiver of the Put Notice (the "Put Date").
