Unauthorized Use of Technology Indemnification
Unauthorized Use of Technology Indemnification Sample Clauses
Related to Unauthorized Use of Technology Indemnification
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense. 1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement. 1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement. 1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Intellectual Property Rights and Indemnification Any intellectual property which originates from or is developed by a Party shall remain in the exclusive ownership of that Party. No license in patent, copyright, trademark or trade secret, or other proprietary or intellectual property right now or hereafter owned, controlled or licensable to a Party, is granted to the other Party or shall be implied or arise by estoppel. It is the responsibility of each Party to ensure at its own cost that it has obtained any necessary licenses in relation to intellectual property of third Parties used by it to receive any service or to perform its respective obligations under this Agreement.
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim
Intellectual Property Indemnification Supplier agrees to defend, indemnify, and hold harmless DXC and its affiliates, subsidiaries, assigns, agents, subcontractors, distributors and customers (collectively “Indemnitees”) from and against all claims, losses, demands, fees, damages, liabilities, costs, expenses, obligations, causes of action, suits, or injuries, of any kind or nature, arising from: (i) any claim that Supplier’s Products or Services, or the use, sale or importation of them, infringes any intellectual property right. Without limiting the foregoing, Supplier will pay all costs, damages and expenses (including reasonable attorneys’ fees) incurred by DXC and/or its Indemnitees and will pay any award with respect to any such claim or agreed to in settlement of that claim.
Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”): (a) breach by Licensee of any duty, covenant or agreement contained in this Agreement or a lawsuit, action, or claim brought by any third party that includes any allegation which, if proven true, would constitute a breach by Licensee of any duty, covenant or agreement contained in this Agreement; (b) the development, use, manufacture, promotion, sale, distribution or other disposition of any Products by Licensee, its Affiliates, assignees, vendors or other third parties, for personal injury, including death, or property damage arising from any of the foregoing. The indemnification obligation under Article 6.3 shall not apply to any contributory negligence or product liability of the Indemnified Party which may have occurred prior to the execution of this Agreement. Licensee will indemnify and hold harmless the Indemnified Parties from and against any Liabilities resulting from: (i) any product liability or other claim of any kind related to the use by a third party of a Product that was manufactured, sold, distributed or otherwise disposed by Licensee, its Affiliates, assignees, vendors or other third parties; (ii) clinical trials or studies conducted by or on behalf of Licensee relating to any Products, including, without limitation, any claim by or on behalf of a human subject of any such clinical trial or study, any claim arising from the procedures specified in any protocol used in any such clinical trial or study, any claim of deviation, authorized or unauthorized, from the protocols of any such clinical trial or study, any claim resulting from or arising out of the manufacture or quality control by a third party of any substance administered in any clinical trial or study; (iii) Licensee’s failure to comply with all prevailing laws, rules and regulations pertaining to the development, testing, manufacture, marketing and import or export of Products.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless the INFI Indemnitees from and against any and all losses, damages, fees, expenses, settlement amounts or costs (including reasonable legal expense, attorneys’ fees and witness fees) (“Losses”) relating to or in connection with a Third Party claim to the extent arising out of (a) the research, development, manufacture or commercialization of the IPI-145 Compound or the IPI-145 Product by Licensee, any Licensee Affiliate, any Sublicensee, INFI (to the extent properly acting in accordance with Licensee’s express direction) or any of their respective employees, consultants, contractors, subcontractors or agents after the Effective Date, including any actual or alleged death, personal bodily injury or damage to real or tangible personal property, or other product liability claimed to result from the IPI-145 Product Researched, Developed, Manufactured or Commercialized by or on behalf of Licensee or any of its Affiliates or any Sublicensee, (b) any breach by Licensee of any of its representations, warranties, covenants or obligations under this Agreement, or (c) any negligent act or omission or willful misconduct of Licensee, any of its Affiliates or any Sublicensee, or any of their respective employees, consultants, contractors, subcontractors or agents, in performing Licensee’s obligations or exercising Licensee’s rights under this Agreement; except that the foregoing indemnity shall not apply with respect to any INFI Indemnitee to the extent that any such Losses (x) are caused by the gross negligence or willful misconduct of any INFI Indemnitee, or (y) are otherwise subject to an obligation by INFI to indemnify the Licensee Indemnitees under Section 10.2.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT The provisions of this clause shall be applicable only if the amount of this Agreement exceeds $100,000. (a) The Contractor shall report to the Government through BSA promptly and in reasonable written detail, each notice or claim of patent or copyright infringement based on the performance of this Agreement of which the Contractor has knowledge. (b) In the event of any claim or suit against the Government on account of any alleged patent or copyright infringement arising out of the performance of this Agreement or out of the use of any supplies furnished or work or services performed hereunder, the Contractor shall furnish to the Government when requested by the Government or BSA, all evidence and information in possession of the Contractor pertaining to such suit or claim. Such evidence and information shall be furnished at the expense of the Government except where the Contractor has agreed to indemnify the Government or BSA. (c) This clause shall be included in all subcontracts.
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
