Underground Utility Facilities Sample Clauses

Underground Utility Facilities. To the extent required by Section 4215 of the California Government Code, District shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of District to provide for removal or relocation of such utility facilities.
Sample 1Sample 2Sample 3See All (48)
AutoNDA by SimpleDocs
Underground Utility Facilities. To the extent required by Section 4215 of the Government Code, City shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of City to provide for removal or relocation of such utility facilities.
Sample 1Sample 2
Underground Utility Facilities. To the extent required by Section 4215 of the California Government Code, MCDH shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of MCDH to provide for removal or relocation of such utility facilities.
Sample 1
Underground Utility Facilities. To the extent required by Section 4215 of the Government Code, County shall compensate Contractor for the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings; and (3) equipment necessarily idled during such work. Contractor shall not be assessed liquidated damages for delay caused by failure of County to provide for removal or relocation of such utility facilities.
Sample 1
Underground Utility Facilities. (Paragraphs deleted) § 3.20.1 The Contractor, at least two (2) working days prior to commencing construction in an area that may involve underground utility facilities, will give notice to the Owner and to the registered underground utility protection services and the owners of underground utility facilities shown on the Drawings and Specifications. § 3.20.2 The Contractor shall notify immediately the occupants of any premises near the Work and the Owner as to any emergency that it may create or discover. The Contractor shall notify immediately the operator of any underground utilities and the Owner of any break or leak in the lines of such operator or any dent, gouge, groove, or other damage to such lines or to their rating or cathodic protection made or discovered in the course of excavation.
Sample 1
Underground Utility Facilities. With reference to Section 42 15 of the California Government Code, the County and the Program Manager agree that the Maximum Price contemplates the costs of: (1) locating and repairing damage to underground utility facilities not caused by the failure of the Program Manager, Construction Manager or any Prime Contractor to exercise reasonable care; (2) removing or relocating underground utility facilities not indicated in the construction drawings, but otherwise known or not constituting Differing Site Conditions; and (3) equipment necessarily idled during such work.
Sample 1

Related to Underground Utility Facilities

  • Underground Facilities All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including without limitation those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems.

  • Underground Utilities Any required ground digging or subsurface work shall be done in accordance with Chapter 556, Florida Statutes. It shall be the responsibility of CONTRACTOR to have all underground utilities located before any work begins (Sunshine State One Call 0-000-000-0000). The repairs of any damaged underground utilities as a result of the work being performed by CONTRACTOR shall be the responsibility of CONTRACTOR. The proper utility company shall be contacted immediately to expedite the repairs, if damage has occurred. CONTRACTOR will notify the COUNTY and provide a written explanation of the incident within two (2) days of the damage to any underground utilities.

  • Underground Tanks If underground or other storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks.

  • Underground Storage Tanks In accordance with the requirements of Section 3(g) of the D.C. Underground Storage Tank Management Act of 1990, as amended by the District of Columbia Underground Storage Tank Management Act of 1990 Amendment Act of 1992 (D.C. Code § 8-113.01, et seq.) (collectively, the “UST Act”) and the applicable D.C. Underground Storage Tank Regulations, 20 DCMR Chapter 56 (the “UST Regulations”), District hereby informs the Developer that it has no knowledge of the existence or removal during its ownership of the Property of any “underground storage tanks” (as defined in the UST Act). Information pertaining to underground storage tanks and underground storage tank removals of which the D.C. Government has received notification is on file with the District Department of the Environment, Underground Storage Tank Branch, 00 X Xxxxxx, X.X., Xxxxx Xxxxx, Xxxxxxxxxx, X.X., 00000, telephone (000) 000-0000. District’s knowledge for purposes of this Section shall mean and be limited to the actual knowledge of Xxxxxx Xxxxx, Property Acquisition and Disposition Division of the Department of Housing and Community Development, telephone no. (000) 000-0000. The foregoing is set forth pursuant to requirements contained in the UST Act and UST Regulations and does not constitute a representation or warranty by District.

  • Toilet Facilities The Employer provides the Contractor access to toilet facilities. Temporary chemical toilets are provided by the Contractor where deemed necessary.

  • Common Facilities “Common Facilities” includes all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Property, and their employees, agents, customers and other invitees, including without limitation building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Property, comfort and first-aid stations, parcel pick-up stations and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord shall have the right, without liability to Tenant, to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time, and Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to enforce parking charges (by operation of meters or otherwise), with appropriate provisions for free parking ticket validating by tenants; to close all or any portion of the Common Facilities to such extent as may, in the opinion of Landlord’s counsel, be legally sufficient to prevent a dedication thereof or the accrual of any rights to any person or the public therein; to close temporarily all or any portion of the Common Facilities; to discourage non-customer parking; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, Tenant may use all Common Facilities not within the Premises, under a revocable license, on a nonexclusive basis in common with other tenants. If any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.

  • Verizon OSS Facilities Any gateways, interfaces, databases, facilities, equipment, software, or systems, used by Verizon to provide Verizon OSS Services to ICG.

  • Laundry Facilities Washers and dryers are installed in each apartment for the exclusive use of students in the apartment. Any other use is prohibited. The use of washers and dryers are free. LINEN: Brighton provides a mattress cover on all mattresses. Students need to bring their own bedding. All beds are regular twin size. The typical cost for replacing a mattress cover is $25.00. MAINTENANCE: Students are responsible to notify the manager in writing as soon as possible if they notice anything in an apartment that requires repair work or maintenance. See “Property Conditions” section 12 of the BYU-Idaho Student Landlord Housing Contract.

  • Interconnection Facilities 4.1.1 The Interconnection Customer shall pay for the cost of the Interconnection Facilities itemized in Attachment 2 of this Agreement. The NYISO, in consultation with the Connecting Transmission Owner, shall provide a best estimate cost, including overheads, for the purchase and construction of its Interconnection Facilities and provide a detailed itemization of such costs. Costs associated with Interconnection Facilities may be shared with other entities that may benefit from such facilities by agreement of the Interconnection Customer, such other entities, the NYISO, and the Connecting Transmission Owner. 4.1.2 The Interconnection Customer shall be responsible for its share of all reasonable expenses, including overheads, associated with (1) owning, operating, maintaining, repairing, and replacing its own Interconnection Facilities, and

  • Generating Facility The Interconnection Customer’s device for the production of electricity identified in the Interconnection Request, but shall not include the Interconnection Customer’s Interconnection Facilities.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!