Project Description In two or three brief sentences, provide a concise description of your exhibition. Include the subject matter, type of objects to be included (paintings, sculpture, manuscripts, etc.), those responsible for organizing the exhibition, and catalogue author(s).
General Project Description 2. Substation location.
VEHICLE DESCRIPTION The vehicles approved for use in the Services shall be Vehicle Type A Chassis Manufacturer and Type ADL Enviro 200 Body Manufacturer and Type ADL Enviro 200 Single or Double Deck Single Deck Upper Deck Air Cooling System Not Applicable Minimum Seating Capacity 29 + 1 Wheelchair Maximum Standing Capacity 28 Maximum Length 10,700mm Maximum Width 2,400mm Number of Doors Two Year of Manufacture 2008 Engine Type (Including Euro Rating) Euro IV Notes: Where appropriate the utilisation of the respective Vehicle Types is shown in Schedule IB. FRAMEWORK AGREEMENT NO: QC0015 ROUTE AGREEMENT NO: QC43403 ROUTE: B15 SCHEDULE IIIA FARE CHART The Fare chart relating to this Route Agreement will be provided by the Corporation prior to the Commencement Date and from time to time during the life of the Route Agreement. In accordance with Schedule II of the Route Agreement, a current fare chart shall be displayed or be available for inspection by members of the public on each vehicle used to operate the Services. The Operator’s obligations in respect of fare collection arrangements, ticket checking and inspection remain unchanged. FRAMEWORK AGREEMENT NO: QC0015 ROUTE AGREEMENT NO: QC43403 ROUTE: B15 VERSION NO: 00 EFFECTIVE DATE: 25 JANUARY 2014 SCHEDULE IVA CONTRACT PRICE AND OTHER FINANCIAL DETAILS
Service Description The Parties will provide Common Channel Signaling (CCS) to one another via Signaling System 7 (SS7) network Interconnection, in accordance with prevailing industry standards. Use of a third party provider of SS7 trunks is permitted.
Service Descriptions Available services for Transitional and Enhanced Supervision Services a. One (1) one-to-one meeting with the Contractor per week for case management services.
Contract Description The Description and Location of the Contract and related project(s) are as follows.
Site Description 2.5.1 If reasonably requested by the A/E as necessary for the Project, the Owner shall furnish a legal description and a certified land survey of the Site, giving, as applicable, grades and lines of streets, alleys, pavements and adjoining property; rights-of-way, restrictions, easements, encroachments, zoning, deed restrictions, boundaries and contours of the Site; locations, dimensions, and complete data pertaining to existing buildings, other improvements, and trees; and full information concerning available service and utility lines, both public and private, above and below grade, including inverts and depths.
Project Location & Description The Project, for which the provision of financial assistance is the subject of this Agreement, is hereby described as follows:
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
