Refund After Non-Approval or Rejection If you or any co-applicant is disapproved or denied under Paragraph 5, we’ll refund all application deposits within 7 days of such disapproval. Refund checks may be made payable to all co-applicants and mailed to one applicant. If the application deposit was paid via check and has not yet been deposited, you may request your check be destroyed instead of a refund check being issued.
Agreement to Pay Attorneys’ Fees and Expenses In the event the Company should default under any of the provisions of this Lease Agreement and the Agency should employ attorneys or incur other expenses for the collection of amounts payable hereunder or the enforcement of performance or observance of any obligations or agreements on the part of the Company herein contained, the Company shall, on demand therefor, pay to the Agency the reasonable fees of such attorneys and such other expenses so incurred.
NO PREJUDICIAL OR RESTRICTIVE MEASURES 1 Neither of the Contracting Parties shall apply prejudicial or restrictive measures based on harmful tax practices to residents or nationals of either Contracting Party so long as this Agreement is in force and effective.
Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.
CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is September 26, 2016. The completion date for this contract is October 31, 2017. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Two Thousand Dollars ($ 2,000.00) per calendar day.
Concurrent Delay When the completion of the Work is simultaneously delayed by an excusable delay and a delay arising from a cause not designated as excusable, Contractor may not be entitled to a time extension for the period of concurrent delay.
EFFECT OF PROPERTY VALUE APPEAL OR OTHER ADJUSTMENT If the Applicant has appealed any matter relating to the valuations placed by the Appraisal District on the Applicant’s Qualified Property, and such appeal remains unresolved at the time the Third Party selected under Section 4.3 makes its calculations under this Agreement, the Third Party shall base its calculations upon the values placed upon the Applicant’s Qualified Property by the Appraisal District. The calculations shall be readjusted, if necessary, based on the outcome of the appeal as set forth below. In the event that the Taxable Value of the Qualified Property is changed after an appeal of its valuation, or the Taxable Value is otherwise altered for any reason, the calculations required under Article IV of this agreement shall be recalculated by the Third Party at Applicant’s sole expense using the revised property values. If as a result of an appeal or for any other reason, the Taxable Value of the Applicant’s Qualified Property is changed, once the determination of the new Taxable Value becomes final, the Parties shall immediately notify the Third Party who shall immediately issue new calculations for the applicable year or years using the new Taxable Value. In the event the new calculations result in a change in any amount paid or payable by the Applicant under this Agreement, the Party from whom the adjustment is payable shall remit such amount to the other Party within thirty (30) days of the receipt of the new calculations from the Third Party.
No Injunctions or Restraints; Illegality No order, injunction or decree issued by any court or agency of competent jurisdiction or other legal restraint or prohibition preventing the consummation of the Merger or any of the other transactions contemplated by this Agreement shall be in effect. No statute, rule, regulation, order, injunction or decree shall have been enacted, entered, promulgated or enforced by any Governmental Entity which prohibits or makes illegal consummation of the Merger.
Attorney’s Fee If any legal action or any arbitration or other proceeding is brought for the enforcement or interpretation of this Agreement, or because of an alleged dispute, breach, default or misrepresentation in connection with or related to this Agreement, the successful or prevailing party shall be entitled to recover reasonable attorneys' fees and other costs in connection with that action or proceeding, in addition to any other relief to which it or they may be entitled.
Permit Suspension or Revocation The Service may suspend or revoke the permit for cause in accordance with the laws and regulations in force at the time of such suspension or revocation (50 CFR 13.28(a)). The Service may also, as a last resort, revoke the permit if continuation of permitted activities would likely result in jeopardy to covered species (50 CFR 17.22/32(d)(7)). The Service will revoke because of jeopardy concerns only after first implementing all practicable measures to remedy the situation.
