Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Termination by Licensee 10.1 Licensee will have the right at any time to terminate this Agreement in whole or as to any portion of Patent Rights by giving notice in writing to The Regents. Such Notice of Termination will be subject to Article 18. (Notices) and termination of this Agreement will be effective sixty (60) days after the effective date thereof.
Termination by Licensor Licensor, at its option, may immediately terminate the Agreement, or any part of Patent Rights, or any part of Field, or any part of Territory, or the exclusive nature of the license grant, upon delivery of written notice to Licensee of Licensor’s decision to terminate, if any of the following occur:
ABANDONMENT OR TERMINATION BY LICENSEE Except as permitted in Section X or XI above, termination of this License Agreement or abandonment of the premises by Licensee may not release Licensee from paying any obligation due the University for so long as the University does not terminate Licensee’s right to an assigned bed space. In the event of termination or abandonment, Licensee may have the right to be released from this agreement if a suitable replacement is found, pursuant to campus regulations and with consent of the University, which consent shall not reasonably be withheld.
Termination by Supplier Termination by Supplier will not be considered.
TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Indemnification by Customer Customer shall indemnify, defend and hold harmless MSIL and its affiliates from and against any loss, liability, damage, cost or expense (including attorneys' and accountants' fees and expenses incurred in the defense of any demands, claims or lawsuits) actually and reasonably incurred arising from any act, omission, conduct, or activity undertaken by MSIL on behalf of Customer, including, without limitation, any demands, claims or lawsuits initiated by a limited partner (or assignee thereof); provided that (i) MSIL has determined, in good faith, that the act, omission, conduct, or activity giving rise to the claim for indemnification was in the best interests of the Customer, and (ii) the act, omission, conduct or activity that was the basis for such loss, liability, damage, cost or expense was not the result of misconduct or negligence. Notwithstanding the foregoing, no indemnification of MSIL or its affiliates by Customer shall be permitted for any losses, liabilities or expenses arising from or out of any alleged violation of federal or state securities laws unless (i) there has been a successful adjudication on the merits of each count involving alleged securities law violations as to the particular indemnitee, or (ii) such claims have been dismissed with prejudice on the merits by a court of competent jurisdiction as to the particular indemnitee, or (iii) a court of competent jurisdiction approves a settlement of the claims against the particular indemnitee and finds that indemnification of the settlement and related costs should be made, provided with regard to such court approval, the indemnitee must apprise the court of the position of the SEC and the positions of the respective securities administrators of Massachusetts, Missouri, Tennessee and/or those other states and jurisdictions in which the plaintiffs claim that they were offered or sold Units, with respect to indemnification for securities laws violations before seeking court approval for indemnification. Furthermore, in any action or proceeding brought by a limited partner in the right of Customer to which MSIL or any affiliate thereof is a party defendant, any such person shall be indemnified only to the extent and subject to the conditions specified in the Delaware Revised Uniform Limited Partnership Act, as amended, and this Section 2. The Customer shall make advances to MSIL or its affiliates hereunder only if: (i) the demand, claim lawsuit or legal action relates to the performance of duties or services by such persons to Customer; (ii) such demand, claim lawsuit or legal action is not initiated by a limited partner; and (iii) such advances are repaid, with interest at the legal rate under Delaware law, if the person receiving such advance is ultimately found not to be entitled to indemnification hereunder.
Customer Liability Customer is solely liable in respect of any loss or cost (including losses or costs suffered by third parties) due to goods not being stored or handled in accordance with this clause 8.
Use by Third Parties You may permit Authorized Third Parties to exercise the Usage Rights on Your behalf, provided that You are responsible for (a) ensuring that such Authorized Third Parties comply with this XXXX and (b) any breach of this XXXX by such Authorized Third Parties.
Termination by the Customer The Customer may terminate this Agreement by providing a written notice of termination to the Transfer Agent, specifying the date as of which this Agreement will terminate, which may be any date, including the date such written notice is provided, provided the circumstances described below giving rise to the termination right are continuing at the time of the Transfer Agent’s receipt of such written notice, if as a result of an Event Beyond Reasonable Control:
