Withholdings for Third Party Claims Sample Clauses

Withholdings for Third Party Claims. Contractor shall, promptly upon notice by County of withheld amounts pursuant to a third-party claim against Contractor, Design Professionals, or their subcontractors or suppliers, pursue a resolution of the third party claim by settlement, litigation or, if available, arbitration. Contractor's obligations to defend and indemnify under Section 1.04 shall apply to such proceedings.
AutoNDA by SimpleDocs
Withholdings for Third Party Claims. Developer shall, promptly upon notice by County of withheld amounts pursuant to a third-party claim against Developer, Design Professionals, Developer’s Other Consultants, Contractor or their Subcontractors or suppliers, pursue a resolution of the third party claim by settlement, litigation or, if available, arbitration. Developer’s obligations to defend and indemnify under Section 13.02 shall apply to such proceedings.

Related to Withholdings for Third Party Claims

  • Indemnification for Third Party Claims ‌ (a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents. (b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents. (c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that: (i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party; (ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and (iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld. (d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement. (e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions: (i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim. (ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed. (iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.

  • Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).

  • Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.

  • Non-Third Party Claims Upon discovery of any claim for which Buyer has an indemnification obligation under the terms of Section 12.1 which does not involve a claim by a third party against the Indemnitee, the Indemnitee shall give prompt notice to Buyer of such claim and, in any case, shall give Buyer such notice within 30 days of such discovery. A failure by Indemnitee to timely give the foregoing notice to Buyer shall not excuse Buyer from any indemnification liability except to the extent that Buyer is materially and adversely prejudiced by such failure.

  • Third Party Claims Each Notice of Claim given by Acquiror, which involves a third party (a “Third Party Claim”), shall be resolved as follows: (a) If, within thirty (30) days after a Notice of Claim is delivered to the Seller Representative, (x) the Seller Representative produces a notice of election and (y) such notice of election includes a written acknowledgment from the Seller Representative on behalf of the Seller Guarantors and the Sellers (the “Indemnifying Persons”) that the Indemnifying Persons would be required to indemnify the Acquiror Indemnified Persons for all Damages in connection with such Third Party Claim Notice, the Indemnifying Persons shall have the right, but not the obligation to (i) take control of the defense and investigation of such Third Party Claim, (ii) employ and engage attorneys of their own choice (subject to the approval of Acquiror, such approval not to be unreasonably withheld, conditioned or delayed) to handle and defend the same, at the Indemnifying Persons’ sole cost and expense, and (iii) compromise or settle such Third Party Claim, which compromise or settlement shall be made only with the written consent of Acquiror; provided, that such consent will not be required if such settlement includes an unconditional release of the Acquiror Indemnified Persons and provides solely for payment of monetary damages for which the Acquiror Indemnified Persons will be indemnified in full. Notwithstanding the foregoing, the Indemnifying Persons shall not have the right to assume the defense of a Third Party Claim if (1) the Indemnifying Persons fail to actively and diligently conduct the defense of the Third Party Claim (after notice and reasonable opportunity to cure), (2) the Acquiror Indemnified Persons have received advice from counsel that an actual or potential conflict exists between the Acquiror Indemnified Persons and the Indemnifying Persons in connection with the defense of such Third Party Claim, (3) such Third Party Claim seeks a finding or admission of a violation of any criminal Law by an Acquiror Indemnified Person, (4) such Third Party Claim seeks an injunction or other equitable remedies in respect of an Acquiror Indemnified Person or its business, (5) such Third Party Claim relates to a Material Customer or Material Supplier, or (6) such Third Party Claim is reasonably likely to result in Damages that, taken with any other then existing claims under this Article 12, would not be not be fully indemnified hereunder. (b) In the event that the Indemnifying Persons defend the Acquiror Indemnified Persons against a Third Party Claim, the Acquiror Indemnified Persons shall cooperate in all reasonable respects, at the Indemnifying Persons’ request, with the Indemnifying Persons and their attorneys in the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom, including, if appropriate and related to such Third Party Claim, in making any counterclaim against the third party claimant, or any cross complaint against any Person, in each case, at the expense of the Indemnifying Persons. The Acquiror Indemnified Persons may, at their own sole cost and expense, monitor and further participate in (but not control) the investigation, trial and defense of such Third Party Claim and any appeal arising therefrom. (c) Notwithstanding anything to the contrary herein, if the Indemnifying Persons do not assume such defense and investigation or does not acknowledge in writing within thirty (30) days after receipt of the Third Party Claim Notice its obligation to indemnify the Acquiror Indemnified Persons against any Damages arising from such Third Party Claim, then the Acquiror Indemnified Persons shall have the right to retain separate counsel of their choosing, defend such Third Party Claim and have the sole power to direct and control such defense (all at the cost and expense of the Indemnifying Persons if it is ultimately determined that the Acquiror Indemnified Persons are entitled to indemnification hereunder); it being understood that the Acquiror Indemnified Persons’ right to indemnification for a Third Party Claim shall not be adversely affected by assuming the defense of such Third Party Claim. Notwithstanding anything herein to the contrary, whether or not the Indemnifying Persons shall have assumed the defense of such Third Party Claim, the Acquiror Indemnified Persons shall not settle, compromise or pay such Third Party Claim for which they seeks indemnification hereunder without the prior written consent of the Indemnifying Persons, which consent shall not be unreasonably withheld, conditioned or delayed. (d) The Acquiror Indemnified Persons and the Indemnifying Persons shall use commercially reasonable efforts to avoid production of confidential information (consistent with Law), and to cause all communications among employees, counsel and others representing any party to a Third Party Claim to be made so as to preserve any applicable attorney-client or work-product privileges. (e) Notwithstanding anything to the contrary in this Agreement, Section 8.1(d) shall exclusively govern S Corporation Tax Proceedings.

  • Settlement of Third Party Claims Notwithstanding any other provision of this Agreement, the Indemnifying Party shall not enter into settlement of any Third Party Claim without the prior written consent of the Indemnified Party, except as provided in this Section 8.05(b). If a firm offer is made to settle a Third Party Claim without leading to liability or the creation of a financial or other obligation on the part of the Indemnified Party and provides, in customary form, for the unconditional release of each Indemnified Party from all liabilities and obligations in connection with such Third Party Claim and the Indemnifying Party desires to accept and agree to such offer, the Indemnifying Party shall give written notice to that effect to the Indemnified Party. If the Indemnified Party fails to consent to such firm offer within ten days after its receipt of such notice, the Indemnified Party may continue to contest or defend such Third Party Claim and in such event, the maximum liability of the Indemnifying Party as to such Third Party Claim shall not exceed the amount of such settlement offer. If the Indemnified Party fails to consent to such firm offer and also fails to assume defense of such Third Party Claim, the Indemnifying Party may settle the Third Party Claim upon the terms set forth in such firm offer to settle such Third Party Claim. If the Indemnified Party has assumed the defense pursuant to Section 8.05(a), it shall not agree to any settlement without the written consent of the Indemnifying Party (which consent shall not be unreasonably withheld or delayed).

  • Additional Indemnification by the Servicer; Third Party Claims The Servicer shall indemnify the Seller, the Depositor, the Trustee and the Master Servicer (and each of their respective directors, officers, employees and agents) and the Trust Fund, and hold them harmless against any and all Costs that any such indemnified party may sustain in any way related to (i) the failure of the Servicer to perform its duties and service the Mortgage Loans in material compliance with the terms of this Agreement (including, but not limited to its obligation to provide the certification pursuant to Section 5.03(b) hereunder) or for any inaccurate or misleading information provided in the certification required pursuant to Section 5.03(b) or (ii) the failure of the Servicer to cause any event to occur or not to occur which would have occurred or would not have occurred, as applicable, if the Servicer were applying Accepted Servicing Practices under this Agreement. The Servicer shall immediately notify the Seller, the Depositor, the Master Servicer, the Trustee or any other relevant party if a claim is made by a third party with respect to this Agreement or the Mortgage Loans, assume (with the prior written consent of the indemnified party in the event of an indemnified claim) the defense of any such claim and pay all expenses in connection therewith, including counsel fees, promptly pay, discharge and satisfy any judgment or decree which may be entered against it or any other party in respect of such claim and follow any written instructions received from such indemnifying party in connection with such claim. Subject to the Servicer’s indemnification pursuant to Section 6.02, or the failure of the Servicer to service and administer the Mortgage Loans in material compliance with the terms of this Agreement, the Trust Fund shall indemnify the Servicer and hold the Servicer harmless against any and all Costs that the Servicer may sustain in connection with any legal action relating to this Agreement, the Certificates or the origination or Servicing of the Mortgage Loans by any prior owner or servicer, other than any Costs incurred by reason of the Servicer’s willful misfeasance, bad faith or negligence in the performance of duties hereunder or by reason of its reckless disregard of obligations and duties hereunder.

  • Additional Indemnification by the Seller; Third Party Claims (a) The Seller shall indemnify any Purchaser and its present and former directors, officers, employees and agents and the Successor Servicer and its present and former directors, officers, employees and agents, and hold such parties harmless against any and all claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses (including legal fees and expenses incurred in connection with the enforcement of the Seller's indemnification obligation under this Subsection 14.01) and related costs, judgments, and any other costs, fees and expenses that such parties may sustain in any way related to the failure of the Seller to perform its duties and the Interim Servicer to service the Mortgage Loans in strict compliance with the terms of this Agreement or any Reconstitution Agreement entered into pursuant to Section 13 or any breach of any of Seller's representations, warranties and covenants set forth in this Agreement. For purposes of this clause "Purchaser" shall mean the Person then acting as the Purchaser under this Agreement and any and all Persons who previously were "Purchasers" under this Agreement and "Successor Servicer" shall mean any Person designated as the Successor Servicer pursuant to this Agreement and any and all Persons who previously were "Successor Servicers" pursuant to this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!