Exhibit 10.41
Original
Number 2 of
6 Executed
Counterparts
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
GROVE STREET ASSOCIATES OF JERSEY
CITY LIMITED PARTNERSHIP
Landlord
To
DLJ SECURITIES CORPORATION
Tenant
LEASE
Premises: International Financial Tower
Jersey City, New Jersey
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
INDEX
Article Caption Page
------- ------- ----
1. Demise, Premises, Term, Rents 1
2. Use 3
3. Completion of Reconstruction of the Building and
Preparation of the Demised Premises 3
4. When Demised Premises Ready for Occupancy 6
5. Adjustments of Rent 8
6. Adjacent Excavation--Shoring 17
7. Subordination, Notice to Lessors and Mortgagees 18
8. Quiet Enjoyment 19
9. Assignment and Subletting 19
10. Compliance with Laws and Requirements of Public
Authorities 27
11. Insurance 28
12. Rules and Regulations 30
13. Tenant's Changes 31
14. Tenant's Property 33
15. Repairs and Maintenance 34
16. Electricity 34
17. Heat, Ventilation and Air-Conditioning 35
18. Landlord's Other Services, Security 36
19. Access, Changes in Building Facilities, Name 37
20. Notice of Accidents 38
21. Non-Liability and Indemnification 38
22. Destruction or Damage 39
-i-
23. Eminent Domain 42
24. Surrender 44
25. Conditions of Limitation 44
26. Re-Entry by Landlord 45
27. Damages 46
28. Waivers 47
29. No Other Waivers or Modifications 48
30. Curing Tenant's Defaults, Additional Rent 49
31. Broker 49
32. Notices 50
33. Estoppel Certificate, Memorandum 50
34. Arbitration 51
35. No Other Representations, Construction
Governing Law, Consents 52
36. Parties Bound 52
37. Certain Definitions and Construction 53
38. Financing 53
39. Right of First Refusal 54
40. Renewal Options 56
41. Option With Respect to the 10th Floor 59
42. Option With Respect to the 11th Floor 61
43. Name of Building 65
44. Definitions 65
45. Loading Dock, Storage Space, Parking
Spaces, Communication Link 66
46. Landlord's Restriction on Retail Space 67
-ii-
Testimonium, Signatures and Seals 68
Acknowledgments 69
Exhibit A-Description of the Premises
Exhibit B-Diagram of Space
Exhibit C-Work Letter
Exhibit D-Rules and Regulations
Exhibit E-Definitions
Exhibit F-Mortgages and Ground Leases
This Index is included only as a matter of convenience of reference and
shall not be deemed or construed in any way to define or limit the scope of the
following lease or the intent of any provision thereof.
-iii-
LEASE
LEASE, dated July 1, 1987, between GROVE STREET ASSOCIATES OF JERSEY CITY
LIMITED PARTNERSHIP, a New Jersey limited partnership having an office at 00
Xxxxxxxx Xxxxx, Xxxxxxxx, Xxx Xxxxxx 00000 (hereinafter referred to as
"Landlord") and DLJ SECURITIES CORPORATION, a New York corporation having an
office at 000 Xxxxxxxx, Xxx Xxxx, Xxx Xxxx 00000 (hereinafter referred to as
"Tenant").
WITNESSETH:
ARTICLE 1
Demise, Premises, Term, Rents
1.01 Landlord hereby leases to Tenant, and Tenant hereby hires from
Landlord, the premises hereinafter described, in the building located on Grove
Street, in the City of Jersey City, County of Xxxxxx and State of New Jersey
(the aforesaid building and the parking structure attached thereto are
hereinafter called the "Building"), on the parcel of land more particularly
described in Exhibit A (the "Land"), for the term hereinafter stated, for the
rents hereinafter reserved and upon and subject to the conditions (including
limitations, restrictions and reservations) and covenants hereinafter provided.
Each party hereby expressly covenants and agrees to observe and perform all of
the conditions and covenants herein contained on its part to be observed and
performed.
1.02 The premises hereby leased to Tenant are the 3rd through 9th floors
of the Building inclusive and the portion of the mezzanine level indicated by
cross-hatching, all as shown on the floor plans annexed hereto as Exhibit B.
Said premises together with all fixtures and equipment which at the
commencement, or during the term, of this lease are thereto attached (except
items not deemed to be included therein and removable by Tenant as provided in
Article 14) constitute and are hereinafter called the "Demised Premises."
1.03 The term of this lease, for which the Demised Premises are hereby
leased, shall commence on a date (herein called the "Commencement Date") which
shall be (a) the later of (i) May 1, 1989 or (ii) thirty (30) days after the day
on which the Demised Premises are ready for occupancy (as defined in Article 4)
or (b) the day Tenant, or anyone claiming under or through Tenant, first
occupies the Demised Premises (exclusive of the Data Center) for business,
whichever of (a) or (b) occurs earlier, and shall end at noon of the last day of
the calendar month in which occurs the day preceding the twentieth (20th)
anniversary of the Commencement Date, which ending date is hereinafter called
the "Expiration Date", or shall end on such earlier date upon which said term
may expire or be cancelled or terminated pursuant to any of the conditions or
covenants of this lease or pursuant to law. Promptly following the Commencement
Date the parties hereto (hereinafter sometimes referred to as the "parties")
shall enter into a recordable supplementary agreement fixing the dates of the
Commencement Date and the Expiration Date and if they cannot agree thereon
within fifteen (15) days after Xxxxxxxx's request therefor, such dates shall be
determined by arbitration in the manner provided in Article 34.
-1-
1.04 The "rents" reserved under this lease, for the term thereof, shall be
and consist of:
(a) "fixed rent" as follows:
(i) Three Million Nine Hundred Eighty-Two Thousand Three
Hundred Thirty-Seven and 50/100 ($3,982,337.50) per year
($331,861.46 per month) for the first five years of the
term;
(ii) Four Million Nine Hundred Two Thousand One Hundred
Twenty-Nine and 00/100 ($4,902,129.00) per year
($408,510.75 per month) for the second five years of the
term;
(iii) Five Million Eight Hundred Eighty-Three Thousand Five
Hundred Eighty-Two and 50/100 ($5,883,582.50) per year
($490,298.54 per month) for the third five years of the
term; and
(iv) Seven Million Sixty Thousand Two Hundred Ninety-Nine and
00/100 ($7,060,299.00) per year ($588,358.25 per month)
for the last five years of the term.
the fixed rent shall be payable in equal monthly installments in advance
on the first day of each and every calendar month during the term of this
lease (except that Tenant shall pay, upon the execution and delivery of
this lease by Xxxxxx, the sum of $33,944.00 to be applied against the
first rents becoming due under this lease or returned to Tenant in the
event this lease is cancelled in accordance with the provisions hereof
prior to the Commencement Date), and
(b) "additional rent" consisting of all such other sums of money as
shall become due from and payable by Tenant to Landlord hereunder (for
default in payment of which Landlord shall have the same remedies as for a
default in payment of fixed rent),
all to be paid to Landlord at its office, or such other place, or to such agent
and at such place, as Landlord may designate by notice to Tenant, in lawful
money of the United States of America.
1.05 Tenant shall pay the fixed rent and additional rent herein reserved
promptly as and when the same shall become due and payable, without demand
therefor and without any abatement, deduction or setoff whatsoever except as
expressly provided in this lease.
1.06 If the Commencement Date occurs on a day other than the first day of
a calendar month, the fixed rent for such calendar month shall be prorated and
the balance of the first month's fixed rent theretofore paid shall be credited
against the next monthly installment of fixed rent.
-2-
ARTICLE 2
Use
2.01 Tenant shall use and occupy the Demised Premises for general and
executive office use and all uses incidental to securities trading and sales
(including, without limitation, retail securities trading and sales) including,
without limitation, operation of trading floors and trading support systems and
for no other purpose. In connection with, and incidental to, Xxxxxx's use of the
Demised Premises as provided in this Article 2, Tenant may use a portion of the
Demised Premises as: (i) a kitchen facility for the preparation and dispensing
of food to its officers, partners, employees and business guests (but not for
use as a public restaurant); (ii) a mail room; (iii) a word processing center;
(iv) reproduction and copying facilities for Tenant's own business requirements;
(v) a computer and communication system in connection with Tenant's general
business; (vi) employee lounges; (vii) an executive dining room and (viii) areas
providing vending machines for the exclusive use of the officers, employees and
business guests of Tenant.
2.02 If after delivery of possession has occurred any governmental license
or permit, other than a Certificate of Occupancy, shall be required for the
proper and lawful conduct of Tenant's business in the Demised Premises, or any
part thereof, and if failure to secure such license or permit would in any way
affect Landlord, Tenant, at its expense, shall duly procure and thereafter
maintain such license or permit and submit the same for inspection by Landlord.
Tenant shall at all times comply with the terms and conditions of each such
license or permit.
2.03 Landlord shall secure a final certificate of occupancy for the
Demised Premises which shall permit the Demised Premises to be used for office
purposes. Tenant shall not at any time use or occupy, or suffer or permit anyone
to use or occupy, the Demised Premises, or do or permit anything to be done in
the Demised Premises, in violation of the Certificate of Occupancy for the
Demised Premises or for the Building.
ARTICLE 3
Completion Of Construction Of The Building
And Preparation Of The Demised Premises
3.01 (a) Landlord shall use reasonable speed and diligence in
completing the construction of the Building and in preparing the Demised
Premises for Tenant's occupancy. Delivery of possession of the Data Center is
anticipated by September 1, 1988 (herein called the "Data Center Delivery Date")
and the remainder of the Demised Premises shall be "ready for occupancy" (as
defined in Article 4) by March 1, 1989 (herein called the "Initial Space
Delivery Date"), but Landlord shall not be liable to Tenant if the anticipated
date is not met. Landlord intends to (i) obtain a written commitment for a
construction loan substantially in accordance with the terms set forth in the
term sheet of MidLantic Bank dated May 14, 1987, (the "Commitment"), on or
before a date which shall be ninety (90) days from the date this lease is
executed by both Landlord and Tenant (the "Commitment Date"), (ii) complete the
pouring of concrete for the first ten (10) floors of the Building (except the
ground floor slab) on or before
-3-
February 28, 1988; (iii) have formed concrete panels on or before May 30, 1988
sufficient to enclose the Building up to and including the highest floor of the
Demised Premises; (iv) commence installation of the curtain wall and enclose at
least the lowest above-grade floor of the Building which contains office space
on or before May 30, 1988; (v) "top off" the Building, enclose the Demised
Premises and install the Basic Systems (as defined in Subsection (e) of this
Section 3.01) on or before February 1, 1988; and (vi) complete the Building and
work to be performed by Landlord for the purposes of Tenant's occupancy pursuant
to Exhibit C of this lease on or before March 1, 1989. If Landlord shall fail to
obtain the Commitment by the Commitment Date, then Tenant shall have the right
to terminate this lease by giving written notice to Landlord after the
Commitment Date but not later than thirty (30) days after the Commitment Date,
to the effect this lease will be terminated effective immediately. If Landlord
shall fail to construct the Building in accordance with the date set forth in
clause (ii) of this Subsection (a) (as such date may have been extended in
accordance with the provisions of Subsection (b) of this Section 3.01), then
Tenant shall have the right to terminate this lease by giving written notice to
Landlord, after August 31, 1988 but not later than September 30, 1988, to the
effect that this lease will be terminated on a designated date which shall be
the later of thirty (30) days from the date of such notice or October 30, 1988
(which date(s) shall also be extended for a period of time equal to an
"Anticipated Delay", as hereinafter defined, for which the date set forth in
clause (ii) of this Subsection (a) may have been extended). If Landlord shall
fail to construct the Building in accordance with any of the dates set forth in
clauses (iii) and (iv) of this Subsection (a) (as such dates may have been
extended in accordance with the provisions of Subsection (b) of this Section
3.01), then Tenant shall have the right to terminate this lease by giving
written notice to Landlord after November 30, 1988 but not later than December
30, 1988 (which date(s) shall also be extended for a period of time equal to an
"Anticipated Delay", as hereinafter defined, for which the dates set forth in
clause (iii) and (iv) of Subsection (a) may have been extended), to the effect
that this lease will be deemed terminated on a designated date which shall be at
least thirty (30) days from the date of such notice. Upon the designated date
set forth in any of the aforesaid notices, this lease shall fully expire and be
deemed terminated and Tenant shall be fully released of all obligations of this
lease and shall be entitled to receive from Landlord any monies paid by Tenant
hereunder for advance rent unless prior to such designated date, Landlord shall
in fact have fully and satisfactory completed the applicable phase of
construction in which event the notice of termination shall be rendered null and
void.
(b) In the event that (i) at any time, Landlord desires to
postpone the construction of the Building or delay the construction of the
Building for a period of time which will render construction of the Building in
accordance with the time-table set forth in Subsection (a) of this Section 3.01
impossible under reasonable standards, or (ii) on or before December 31, 1987,
Landlord knows that the Building will not be built or that construction of the
Building has been so delayed for a period of time which will render construction
of the Building in accordance with the time-table set forth in Subsection (a) of
this Section 3.01 impossible under reasonable standards, then and in any such
event Landlord agrees to send a written notice (the "Delay Notice") to Tenant,
which in the case of a Delay Notice under clause (ii) of this Subsection (b)
shall be sent on or before December 31, 1987, indicating the basis for the delay
and the amount of time (the "Anticipated Delay") which Landlord estimates
construction will be delayed. Within twenty (20) days after the receipt of the
Delay Notice, Tenant shall have the right to cancel this lease by giving written
notice thereof to Landlord, whereupon this lease shall fully expire and be
deemed terminated and Tenant shall be fully released of all obligations
-4-
of Tenant hereunder and shall be entitled to receive from Landlord any monies
paid by Tenant hereunder for advance rent. In the event Tenant does not elect to
cancel, then this lease shall continue unmodified, except that the dates
specified in clauses (ii), (iii) and (iv) of Subsection (a) above which are
unfulfilled at the time of the sending of the Delay Notice shall be extended for
a period of time equal to the Anticipated Delay.
(c) Notwithstanding anything to the contrary herein contained,
the date on which rent shall commence (the "Rent Commencement Date") shall be
extended as follows:
(i) the Rent Commencement Date shall be extended by one
day for each day after the Data Center Delivery Date that Landlord
fails to deliver possession of the Data Center in accordance with
the provisions of this lease; and
(ii) the Rent Commencement Date shall be extended by one
day for the excess of (A) each day after the Initial Space Delivery
Date that Landlord fails to deliver possession of the remainder of
the Demised Premises in accordance with the provisions of this lease
over (B) the number of days, if any, by which the Rent Commencement
date has already been extended pursuant to clause (i) of this
Subsection (c) above.
(d) The right of cancellation herein provided and the return
of any monies paid hereunder by Xxxxxx for advance rent shall be Tenant's
exclusive remedies under this lease in the event Landlord fails to comply with
the provisions of this Section 3.01.
(e) As used in this Section 3.01, the term "Basic Systems"
shall mean the HVAC systems and elevators serving the Demised Premises.
3.02 Landlord agrees to construct an 18 story plus penthouse
building containing at least 562,000 square feet of space and an attached
200,000 square foot garage of six levels containing not less than 520 parking
spaces. Approximately 20,000 square feet of the Building may be utilized for
retail use. Xxxxxxxx agrees that the Building will be constructed in accordance
with the final plans and specifications prepared by Xxxxxxx Xxxxxxxx and Xxxxxxx
Xxxxxxx Associates. The final plans and specifications shall substantially
conform to the preliminary plans referred to on Exhibit C. Landlord shall
complete the Building including the exterior and common areas as a first-class
office building substantially in accordance with Existing Plans (as defined in
Exhibit C) and specifications and shall include all the features and things
required by this lease without change therefrom, except
(a) as may be consented to in writing by Xxxxxx (which consent shall
not be unreasonably withheld or delayed), or
(b) as may be necessary to comply with any applicable law or
requirement of public authority and will not (i) materially and adversely
affect any of the services to be rendered by Landlord to Tenant pursuant
to this lease or (ii) materially and adversely affect (A) the layout, (B)
the utility of the Demised Premises, or (C) the usable area of the Demised
Premises.
-5-
3.03 The Demised Premises shall be completed and prepared for
Tenant's occupancy in the manner, and subject to the terms, conditions and
covenants, set forth in Exhibit C. The facilities, materials and work so to be
furnished, installed and performed in the Demised Premises are hereinafter and
in Exhibit C referred to as the Basic Work and the Supplementary Work. Landlord
and Xxxxxx agree to perform their respective obligations under Exhibit C which
is annexed hereto and made a part hereof, and in the event Tenant fails to make
the payments required to be made thereunder, Landlord shall have the remedies
available for non-payment of rent.
3.04 Tenant shall have access to plans and specifications for the
Building at all reasonable times, and Landlord shall deliver to Tenant copies of
such plans and specifications for Tenant's premises together with a layout of
all the floors in the Building for Tenant's review after substantial completion
of the Building but prior to the Commencement Date.
ARTICLE 4
When Demised Premises Ready For Occupancy
4.01 The Demised Premises (exclusive of the Data Center) shall be
deemed ready for occupancy on the earliest date on which all of the following
conditions have been met:
(a) A Certificate of Occupancy (temporary or final) has been issued
by the City of Jersey City, permitting Xxxxxx's use of the Demised
Premises for office purposes;
(b) The Supplementary Work has been substantially completed; and it
shall be so deemed notwithstanding the fact that minor or insubstantial
details of construction, mechanical adjustment, or decoration remain to be
performed, the noncompletion of which does not materially interfere with
Xxxxxx's use of the Demised Premises;
(c) Reasonable means of access taking into account the nature of
Tenant's business and those facilities necessary to Tenant's occupancy of
the Demised Premises, including elevators, toilets, plumbing, water,
lighting and electrical power facilities, have been installed and are in
reasonably good operating order and available to Tenant.
(d) the heating, ventilating and air conditioning system
(hereinafter referred to as "HVAC") shall have been installed, and shall
be in reasonably good operating order;
(e) all facilities and systems serving the Building (including the
Tenant's Loading Dock as defined in Section 45.1) and passing through the
Demised Premises or any part thereof, and at least five (5) elevators
servicing the Demised Premises shall have been substantially completed,
the Building shall be completely enclosed (except as permitted in
subparagraph (f) hereinafter) and all scaffolding shall have
-6-
been removed therefrom, except for a temporary hoist, and the remaining
work to be done on the Building is of such a nature as will not materially
interfere with Tenant's normal use and occupancy of the Demised Premises;
(f) all windows shall have been fully installed in the Building
provided that if all windows have been installed in the Demised Premises
but not in the Building, such condition shall not prevent the readiness of
the Demised Premises as long as the lack of any windows in the Building
does not have materially adverse effect on Xxxxxx's occupancy of the
Demised Premises or the operation of the systems therein;
(g) the lobby, corridors and sidewalks have been substantially
completed to allow access to the Demised Premises and are reasonably
presentable in appearance and there shall be no unreasonable obstructions
therein or thereon;
(h) all Building security systems and any mechanisms to insure the
security of the Demised Premises, have been installed and are operative;
(i) the parking garage has been substantially completed and is
available for use of Tenant's employees;
(j) Notwithstanding the foregoing, the Data Center shall be deemed
ready for occupancy when the "Preliminary Installations" (as defined in
Exhibit C) with respect to the Data Center have been completed, there is
reasonable access thereto for delivery of equipment and employees using
the Data Center shall have reasonable parking facilities available
(provided however Landlord shall not be obligated to construct any
separate parking facilities for such employees).
Landlord shall give Tenant a preliminary notice, (the "Preliminary Notice")
estimating the date (the "Delivery Date") when the conditions listed in
Subsections (a) through (i) above will be met, which Preliminary Notice shall
contain a statement that the effect of Tenant's failure to respond thereto
within thirty (30) days after Xxxxxx's receipt thereof shall be deemed an
acknowledgement that the conditions of Subsection (a) through (i) above have
been met. The Preliminary Notice shall be given by Landlord to Tenant at least
sixty (60) and not more than ninety (90) days prior to the Delivery Date set
forth therein. At any time within thirty (30) days after Tenant shall have
received Landlord's Preliminary Notice referred to in the preceding sentence,
Tenant may send Landlord written notice (the "Objection Notice") of those
conditions listed in subsections (a) through (i), completion of which Tenant
deems essential for Tenant's occupancy of the premises, and which Tenant
reasonably believes will not be completed by the Delivery Date. Upon receipt of
Tenant's Objection Notice, Landlord shall either (i) extend the Delivery Date
for a period reasonably needed by Landlord to complete the work specified in
Tenant's Objection Notice (which shall not be less than thirty (30) days), or
(ii) notify Tenant that Landlord will complete those conditions listed in
Tenant's Objection Notice on or before the Delivery Date, and in the event
Landlord fails so to do, Landlord shall indemnify Tenant for any damages
sustained as a result of Landlord's failure so to do. Any dispute as to damages
sustained by Tenant shall be submitted to arbitration in accordance with Article
34 hereof.
-7-
4.02 If the occurrence of any of the conditions listed in Section 4.01,
and thereby the making of the Demised Premises ready for occupancy, shall be
delayed due to any act or omission of Tenant or any of its employees, agents or
contractors or any failure (not due to any act or omission of Landlord or any of
its employees, agents or contractors) to plan or execute Tenant's Work
diligently and expeditiously, which shall continue after Landlord shall have
given Tenant reasonable notice that such act, omission or failure would result
in delay, and such delay shall have been unavoidable by Landlord in the exercise
of reasonable diligence and prudence, the Demised Premises shall be deemed ready
for occupancy on the date when they would have been ready but for such delay.
4.03 If and when Tenant shall take actual possession of the Demised
Premises, it shall be conclusively presumed that the same were in satisfactory
condition (except for latent defects and except for items which, because of the
seasonal nature of their use, would not, in the ordinary course of Tenant's
business, be detected within such ninety (90) day period) as of the date of such
taking of possession, unless within ninety (90) days after Tenant takes
possession of the Demised Premises Tenant shall give Landlord notice specifying
the respects in which the portions of the Demised Premises which Xxxxxx has
taken possession of were not in satisfactory condition.
4.04 In the event that as a result of Landlord's maintenance of a
construction hoist Tenant shall be unable to use a portion of the Demised
Premises, Tenant shall be entitled to an abatement of rental representing the
rental payable on the portion of the premises which is not useable. Such
abatement shall continue so long as the temporary hoist shall exist. Landlord
will use reasonable efforts to remove such hoist within twelve (12) months after
the Commencement Date.
4.05 Xxxxxxxx agrees to obtain a Final Certificate of Occupancy for the
entire Building after completion thereof.
ARTICLE 5
Adjustments Of Rent
5.01 Tax Escalation. For the purpose of Sections 5.01-5.06:
(a) "Taxes" shall mean the real estate taxes and assessments
(exclusive of penalties and interest) and special assessments imposed upon the
Building and the Land or payments required to be made to any governmental
authority in lieu thereof. If at any time during the term of this lease the
methods of taxation prevailing at the commencement of the term hereof shall be
altered so that in lieu of or as an addition to or as a substitute for the whole
or any part of the taxes, assessments, levies, impositions or charges now
levied, assessed or imposed on real estate and the improvements thereon, there
shall be levied, assessed or imposed (i) a tax, assessment, levy, imposition or
charge wholly or partially as capital levy or otherwise on the rents received
therefrom, or (ii) a tax, assessment, levy, imposition or charge measured by or
based in whole or in part upon the Demised Premises and imposed upon Landlord,
or (iii) a license fee measured by the rents payable by Tenant to Landlord, then
all such taxes, assessments, levies, impositions or charges, or the part thereof
so measured or based, shall be deemed to be included
-8-
within the term "Taxes" for the purposes hereof. Anything contained herein to
the contrary notwithstanding, Taxes shall not be deemed to include (i) any taxes
on Landlord's income, (ii) franchise taxes, (iii) estate or inheritance taxes or
(iv) any similar taxes imposed on Landlord, unless such taxes are levied, or
assessed or imposed in lieu of or as a substitute for the whole or any part of
the taxes, assessments, levies, or impositions which now constitute Taxes.
(b) "Tax Year" shall mean the fiscal year for which Taxes are levied
by the governmental authority.
(c) "Initial Tax Year" shall mean the Tax Year in which the
Commencement Date occurs.
(d) "Initial Tax Period" shall mean that portion of the Initial Tax
Year between the Commencement Date and the expiration of the Initial Tax Year.
(e) "Tenant's Proportionate Share" shall mean for purposes of this
lease and all calculations in connection with Sections 5.01-5.06 41.31% which
has been computed on the basis of a fraction, the numerator of which is the
agreed rentable square foot area of the Demised Premises as set forth below
(which rentable square foot area is hereinafter sometimes referred to as the
"Multiplication Factor") and the denominator of which is the agreed rentable
square foot area of the Building above grade level as set forth below. The
parties agree that the rentable square foot area of the Demised Premises shall
be deemed to be 256,925 square feet and that the agreed rentable square foot
area of the Building above grade (excluding the garage) shall be deemed to be
621,900 square feet (the "Building Area"). In the event the Building Area shall
be increased above 621,900 square feet (excluding the garage), Tenant's
Proportionate Share shall be recomputed to reflect such increase.
(f) "Total Initial Tax Share" shall mean the amount of the Taxes
paid or to be paid by Landlord for the Initial Tax Period (i.e., the Taxes
payable for the Initial Tax Year multiplied by a fraction, the numerator of
which is the number of days between the Commencement Date and the expiration of
the Initial Tax Year, and the denominator of which is 365).
(g) "Tenant's Initial Tax Share" shall mean an amount equal to the
Total Initial Tax Share multiplied by Tenant's Proportionate Share.
(h) "Projected Taxes" shall mean the anticipated amount of Taxes
which will be imposed for a Tax Year (based on the average annual increase over
the immediately preceding three (3) year period (or such shorter period as may
have actually elapsed since the Commencement Date, or, in the case of the first
Tax Year after the Initial Tax Year, an amount representing a reasonable
increase over the previous year).
(i) "Actual Taxes" shall mean the actual Taxes imposed for a Tax
Year.
(j) "Tenant's Projected Share of Taxes" shall mean an amount equal
to the Projected Taxes multiplied by Xxxxxx's Proportionate Share and then
divided by number of payment periods in the Tax Year in question (which periods
shall be measured by reference to the last date on which said Taxes may be paid
without the imposition of any interest or penalty thereon).
-9-
(k) "Tenant's Proportionate Share of Taxes" shall mean the Actual
Taxes multiplied by Xxxxxx's Proportionate Share.
5.02 (a) Within thirty (30) days after the Commencement Date,
Landlord shall furnish Tenant with a written statement (the "Initial Tax
Statement") of (i) the Total Initial Tax Share, and (ii) Tenant's Initial Tax
Share.
(b) Within sixty (60) days after the expiration of the Initial Tax
Year, Landlord shall furnish Tenant with a written statement (the "Second Tax
Statement") indicating (i) the amount of Taxes which Landlord will be required
to pay for the upcoming Tax Year, (ii) the Projected Taxes, and (iii) Landlord's
computation of Tenant's Projected Share of Taxes for the upcoming Tax Year.
(c) Within sixty (60) days after the expiration of each Tax Year
after the Initial Tax Year, Landlord shall furnish Tenant with a written
statement (the "Subsequent Tax Statement") indicating (i) the amount of Taxes
which Landlord will be required to pay for the upcoming Tax Year, (ii) the
Projected Taxes, (iii) Landlord's computation of Tenant's Projected Share of
Taxes for the upcoming Tax Year, (iv) Tenant's Proportionate Share of Taxes for
the Tax Year which has recently expired, and (v) any discrepancy between
Xxxxxx's Proportionate Share of Taxes for the Tax Year which has recently
expired and Xxxxxx's Projected Share of Taxes for such Tax Year.
(d) Payments of rental in accordance with the Initial Tax Statement,
Second Tax Statement and Subsequent Tax Statements shall be made at the times
specified in Section 5.05.
5.03 (a) Landlord represents that the Building has been granted a tax
exemption under the Xxx-Xxxxx statute.
(b) Notwithstanding the fact that the increase in rent is measured
by an increase in Taxes, such increase is additional rent and shall be paid by
Tenant as provided herein regardless of the fact that Tenant may be exempt, in
whole or in part, from the payment of any taxes by reason of Tenant's diplomatic
or other tax exempt status or for any other reason whatsoever.
5.04 Subject to the provisions of Section 5.11, only Landlord shall be
eligible to institute tax reduction or other proceedings to reduce the assessed
valuation of the Land and Building. Should Landlord be successful in any such
reduction proceedings and obtain a rebate for periods during which Tenant has
paid its share of increases or received the benefit of any decreases, Landlord
shall after deducting its expenses, including without limitation, attorneys'
fees and disbursements in connection therewith, return Xxxxxx's Proportionate
Share of such rebate to Tenant.
5.05 (a) Tenant shall pay to Landlord as additional rent during the
Initial Tax Period, Tenant's Initial Tax Share which shall be payable forty-five
(45) days prior to the date Landlord is required to make any payments to the
taxing authority, the first payment representing the payments retroactive to the
Commencement Date and including the current month shall be made within ten (10)
days after receipt of the Initial Tax Statement, and thereafter payments shall
be made forty-five (45) days prior to the date Landlord is required to make any
payments to the taxing authority, until receipt of the Second Tax Statement.
-10-
(b) Tenant shall pay to Landlord as additional rent during the Tax
Year immediately following the Initial Tax Year, Tenant's Projected Share of
Taxes as indicated on the Second Tax Statement, except that the first payment
representing the payments retroactive to the first day of the current Tax Year
shall be made within ten (10) days after receipt of the Second Tax Statement,
and thereafter normal payments shall be made during such Tax Year forty-five
(45) days prior to the date Landlord is required to make any payments to the
taxing authority, until receipt of the Subsequent Tax Statement.
(c) Tenant shall pay to Landlord as additional rent during each Tax
Year thereafter Xxxxxx's Projected Share of Taxes as indicated on a Subsequent
Tax Statement, the first payment representing the payments retroactive to the
first day of the current Tax Year and including the current month shall be made
within ten (10) days after receipt of the Subsequent Tax Statement, and
thereafter normal payments shall be made forty-five (45) days prior to the date
Landlord is required to make any payments to the taxing authority, thereafter
during such Tax Year until receipt of the Subsequent Tax Statement.
5.06 (a) If any statement furnished by Landlord to Tenant pursuant to
Section 5.02 at the end of a recently expired Tax Year shall indicate that
Tenant's Projected Share of Taxes for such recently expired Tax Year exceeded
Tenant's Proportionate Share of Taxes for such recently expired Tax Year,
Landlord shall within ten (10) days refund the amount of excess to Tenant
together with interest at the Agreed Rate. If such statement furnished by
Landlord to Tenant hereunder shall indicate that the Tenant's Proportionate
Share of Taxes for such recently expired Tax Year exceeded Tenant's Projected
Share of Taxes for such recently expired Tax Year or if Landlord shall, at any
time, pay any Taxes which, if adjusted to reflect the full Tax Year, shall or
would exceed the Projected Taxes, Tenant shall, within ten (10) days after
receipt of such statement or the notice advising Tenant of the discrepancy in
the Projected Tax Differential, pay the amount of any deficiency to Landlord as
additional rent together with interest at the Agreed Rate, and the subsequent
payments of Xxxxxx's Projected Share of Taxes shall be increased accordingly.
(b) Anything in Sections 5.05 or 5.06(a) to the contrary
notwithstanding, in the event that the holder of any superior mortgage or the
lessor of any superior lease (as such terms are defined in Section 7.01 hereof)
shall require advance payments from the Landlord on account of Taxes, then
Tenant will pay Tenant's Proportionate Share of any amounts required to be paid
in advance by Landlord with the holder of the superior mortgage or the lessor of
the superior lease. Any payments to be made by Tenant under Section 5.06(b)
shall be made within ten (10) days prior to the date Landlord is required to
make such payments to the holder of the superior mortgage or the lessor of the
superior lease. If interest is paid on the payments made to the holder of the
superior mortgage or the lessor of the superior lease Tenant shall receive
Tenant's Proportionate share of such interest within ten (10) days after it is
received by or credited to Landlord.
(c) Xxxxxxxx's failure to render any statement required to be
furnished by Landlord to Tenant pursuant to Section 5.02 shall in no way
prejudice Tenant's right to receive a refund for the overpayment of any sums
paid by Xxxxxx on account of Taxes pursuant to this Article 5.
5.07 Expense Escalation. For purposes of Sections 5.07 - 5.ll:
-11-
(a) "Operating Expenses" shall mean any or all expenses incurred by
Landlord in connection with the operation of the Building including all expenses
incurred as a result of Landlord's compliance with any of its obligations
hereunder other than Landlord's Work and such expenses shall include: (i)
salaries, wages, medical, surgical and general welfare benefits, (including
group life insurance) pension payments and other fringe benefits of employees of
Landlord engaged in the operation and maintenance of the Building (The salaries
and other benefits aforesaid of such employees servicing the Building shall be
comparable to those of employees servicing buildings similar to the Building,
located in the County of Xxxxxx); (ii) payroll taxes, workmen's compensation,
uniforms and dry cleaning for the employees referred to in subdivision (i);
(iii) the cost of all charges for steam, heat, ventilation, air conditioning and
water (including sewer rental) furnished to the Building and/or used in the
operation of all of the service and parking facilities of the Building and the
cost of all charges for electricity furnished to the public and service areas of
the Building and/or used in the operation of all of the service and parking
facilities of the Building including any taxes on any of such utilities; (iv)
the cost of all charges for rent, casualty, war risk insurance (if obtainable
from the United States government) and of liability insurance for the Building
to the extent that such insurance is required to be carried by Landlord under
any superior lease or superior mortgage or if not required under any superior
lease or superior mortgage then to the extent such insurance is carried by
owners of Buildings comparable to the Building; (v) the cost of all building and
cleaning supplies for the common areas of the Building and charges for
telephones for the Building; (vi) the cost of all charges for management, window
cleaning and service contracts for the Building and the parking and other
service facilities related thereto; (vii) the cost of rentals of capital
equipment designed to result in savings or reductions in Operating Expenses, of
which rentals Landlord shall notify Tenant in reasonable detail at the time of
the rendition of the next Operating Statement (provided, however, Landlord's
failure to render such notice shall not be deemed a waiver of Landlord's right
to collect, or a release of Tenant's obligation to pay, for such items as a part
of Operating Expenses); and Operating Expenses shall not include: (viii)
administrative wages and salaries; (ix) renting commissions; (x) franchise taxes
or income taxes of Landlord; (xi) Taxes on the Land and Building; (xii) costs of
installations, painting and decorating for any occupant's space; (xiii) interest
and amortization under mortgages; (xiv) rent payable under any superior lease;
(xv) expenditures for capital improvements under generally accepted accounting
practice (1) except those which under generally applied real estate practice are
expensed or regarded as deferred expenses and (2) for capital improvements
required by law or (3) for capital improvements which are designed to result in
a saving in the amount of Operating Expenses of which improvement Landlord shall
notify Tenant in reasonable detail at the time of the rendition of the next
Operating Statement (provided, however, Landlord's failure to render such notice
shall not be deemed a waiver of Landlord's right to collect, or a release of
Tenant's obligation to pay, for such item as a part of Operating Expenses), in
any of such cases the cost thereof shall be included in Operating Expenses for
the Operational Year in which the costs are incurred and subsequent Operational
Years, amortized on a straight line basis, to the extent that such items are
amortized over an appropriate period, but not more than ten years, with an
interest factor equal to two (2%) percent above the prime rate of Manufacturer's
Hanover Trust Company at the time of Xxxxxxxx's having incurred said
expenditure; (xvi) the cost of electrical energy furnished to tenants at the
Building; (xvii) salaries of personnel above the grade of building manager and
such building manager's supervisor; (xviii) cost of repairs or replacements
incurred by reason of fire or other casualty or condemnation to the extent
Landlord is compensated therefor during the
-12-
Operational Year to which a Second or Subsequent Operating Statement relates or
would have been compensated therefor if Landlord carried the insurance required
by Section 11.07 hereof, but did not; (xix) advertising and promotional
expenditures; (xx) costs incurred in connection with a transfer or disposition
of the Land or Building; (xxi) any fee or expenditure paid to (y) any
corporation or entity which controls, is controlled by or is under common
control with Landlord, or which Landlord directly or indirectly owns not less
than a twenty-five percent (25%) interest, or (z) to any person who is a
relative by blood (to the first degree of consanguinity, lineal or lateral) or
marriage or any shareholder owning at least fifty percent (50%) of the common
stock, any general partner, any officer above the rank of vice president, or
member of any board of directors of Landlord or of any corporation or entity
described in this clause (xxi), in each case in excess of the amount which would
be paid in the absence of such relationship; (xxii) costs incurred in connection
with the negotiation or enforcement of leases, including court costs and
attorneys' fees and disbursements in connection with any summary proceeding to
dispossess any tenant; (xxiii) depreciation; and (xxiv) any other expenditure
which would otherwise be an Operating Expense to the extent Landlord is
reimbursed therefor from any source other than pursuant to rent provisions in
the nature of this Article 5. There shall be deducted from Operating Expenses
all amounts actually paid to Landlord by tenants, occupants and users of the
parking facilities or retail areas under clauses relating to reimbursement of
Operating Expenses, provided however Landlord shall use reasonable efforts to
endeavor to collect said sums from such tenants, occupants and users.
(b) "Operational Year" shall mean each calendar year or part thereof
occurring during the Term of this lease excluding the Initial Operational Year.
(c) "Initial Operational Year" shall mean the Operational Year in
which the Commencement Date occurs.
(d) "Initial Operating Period" shall mean that portion of the
Initial Operational Year between the Commencement Date and the expiration of the
Initial Operational Year.
(e) "Projected Initial Operating Expense Differential" shall mean
the amount of Operating Expenses Landlord estimates it will incur during the
Initial Operating Period.
(f) "Actual Initial Operating Expense Differential" shall mean the
actual amount of Operating Expenses incurred by Landlord for the Initial
Operating Period (i.e., the Operating Expenses payable for the Initial
Operational Year multiplied by a fraction, the numerator of which is the number
of days between the Commencement Date and the expiration of the Initial
Operational Period, and the denominator of which is 365).
(g) "Tenant's Initial Projected Share of Operating Expenses" shall
mean an amount equal to (i) Tenant's Operational Proportionate Share, multiplied
by (ii) the Projected Initial Operating Expense Differential.
(h) "Tenant's Initial Actual Proportionate Share of Operating
Expenses" shall mean the Actual Initial Operating Expense Differential
multiplied by Tenant's Operational Proportionate Share.
-13-
(i) "Initial Operating Expenses" shall mean the actual amount of
Operating Expenses incurred by Landlord during the Initial Operational Year.
(j) "Comparative Operational Year" shall mean the Operational Year
preceding the recently expired Operational Year.
(k) "Tenant's Operational Proportionate Share" shall mean 41.76%,
which (i) has been computed by dividing the agreed rentable square foot area the
Demised Premises (256,925 square feet) by the Building Area exclusive of retail
space (615,200 square feet) (the "Building Office Area"), and (ii) shall be
subject to recomputation in the event the Building Office Area is increased.
(1) "Tenant's Proportionate Share of Operating Expenses" shall mean
Tenant's Operational Proportionate Share multiplied by the Actual Operating
Expense Differential.
(m) "Operating Expense Increase Factor" shall mean 1.00 for the
Operational Year following the Initial Operational Year and thereafter shall
mean the greater of (i) the actual Operating Expenses for the recently expired
Operational Year divided by the actual Operating Expenses for the Comparative
Operational Year and (ii) 1.05.
(n) "Projected Amount of Operating Expenses" shall mean the
Operating Expense Base For Computations multiplied by the Operating Expense
Increase Factor.
(o) "Projected Operating Expenses" shall mean the amount of the
Projected Amount of Operating Expenses for the upcoming Operational Year.
(p) "Actual Operating Expenses" shall mean the amount of Operating
Expenses actually incurred by Landlord for the recently expired Operational
Year.
(q) "Tenant's Projected Share of Operating Expenses" shall mean
one-twelfth (1/12th) of the product of (i) Tenant's Operational Proportionate
Share, multiplied by (ii) the Projected Operating Expenses for the upcoming
Operational Year.
(r) "Operating Expense Base For Computations" shall mean the greater
of (i) the amount of Operating Expenses which Landlord would have incurred if
the Building were eighty-five (85%) percent occupied throughout the Comparative
Operational Year or (ii) the actual Operating Expenses for the Comparative
Operational Year.
(s) "Tenant's Actual Share of Operating Expenses" shall mean the
product of (i) the Actual Operating Expenses multiplied by (ii) Tenant's
Operational Proportionate Share.
5.08 (a) Within thirty (30) days after the Commencement Date, Landlord
shall furnish Tenant a written detailed statement (the "Initial Operating
Statement") of (i) the Projected Initial Operating Expense Differential and (ii)
Tenant's Initial Projected Share of Operating Expenses.
-14-
(b) Within one hundred twenty (120) days after the expiration of the
Initial Operational Year, Landlord shall furnish Tenant with a written detailed
statement (the "Second Operating Statement") indicating (i) Initial Operating
Expenses, (ii) the Operating Expense Base For Computations as same may have been
revised based on actual expenditures for Operating Expenses made by Landlord
during the Initial Operational Year, (iii) the Projected Operating Expenses for
the upcoming Operational Year, (iv) Landlord's computation of Xxxxxx's Projected
Share of Operating Expenses for the upcoming Operational Year, and (v) the
amount of any discrepancy between Tenant's Initial Actual Proportionate Share of
Operating Expenses and Tenant's Initial Projected Share of Operating Expenses
for the Initial Operating Period. The Second Operating Statement shall be
certified by a financial officer of Landlord with respect to items (i), (ii) and
(v) above.
(c) Within one hundred twenty (120) days after the expiration of the
first Operational Year after the Initial Operational Year and each Operational
Year thereafter, Landlord shall furnish Tenant with a written detailed statement
(a "Subsequent Operating Statement") indicating (i) actual amount of Operating
Expenses for the recently expired Operational Year, (ii) the Operating Expense
Base For Computations as same may have been revised based on actual expenditures
for Operating Expenses made by Landlord during the recently expired Operational
Year, (iii) the Projected Operating Expenses for the upcoming Operational Year,
(iv) the Operating Expense Increase Factor, (v) Landlord's computation of
Xxxxxx's Projected Share of Operating Expenses for the upcoming Operational
Year, and (vi) the amount of any discrepancy between Tenant's Proportionate
Share of Operating Expenses and Tenant's Projected Share of Operating Expenses
for the recently expired Operational Year. The Subsequent Operating Statement
shall be certified by a financial officer of Landlord with respect to items (i),
(ii), (iv) and (vi) above.
(d) Payments of rental in accordance with the Initial Operating
Statement, Second Operating Statement and Subsequent Operating Statements shall
be made at the times specified in Section 5.09.
5.09 (a) Tenant shall pay to Landlord, as additional rent during the
Initial Operating Period, Tenant's Initial Projected Share of Operating
Expenses, which shall be payable monthly, a payment representing the payments
retroactive to the Commencement Date and including the current month shall be
made within ten (10) days after Tenant receives the Initial Operating Statement
and thereafter normal monthly payments shall be made on the first day of each
month throughout the Initial Operating Period and thereafter until receipt of
the Second Operating Statement. If the Second Operating Statement furnished by
Landlord to Tenant for the Initial Operational Year shall indicate that Tenant's
Projected Initial Share of Operating Expenses exceeded Tenant's Actual Share of
Initial Operating Expenses, Landlord shall refund the amount of excess to Tenant
within ten (10) days after delivery of the statement. If, however, the Second
Operating Statement shall indicate that Tenant's Actual Share of Initial
Operating Expenses exceeded Tenant's Initial Projected Share of Operating
Expenses, Tenant shall, within ten (10) days, pay the amount of such excess to
Landlord as additional rent.
(b) Tenant shall pay to Landlord, as additional rent during the
first Operational Year after the Initial Operational Period, Tenant's Projected
Share of Operating Expenses, which shall be payable monthly, the first payment
representing the
-15-
payments retroactive to the first day of the current Operational Year and
including the current month after crediting Tenant with payments made for the
current Operational Year but made prior to the receipt of the Second Operating
Statement shall be made within ten (10) days after Xxxxxx receives the Second
Operating Statement, and thereafter normal monthly payments shall be made on the
first day of each month throughout the current Operational Year and thereafter
until receipt of the Subsequent Operating Statement. If the Subsequent Operating
Statement furnished by Landlord to Tenant for the recently expired Operational
Year shall indicate that Tenant's Projected Share of Operating Expenses exceeded
Tenant's Actual Share of Operating Expenses, Landlord shall refund the amount of
excess to Tenant within ten (10) days after delivery of the statement. If,
however, the Subsequent Operating Statement shall indicate that Tenant's Actual
Share of Operating Expenses exceeded Tenant's Projected Share of Operating
Expenses, Tenant shall, within ten (10) days, pay the amount of such excess to
Landlord as additional rent.
(c) Tenant shall pay to Landlord, as additional rent during each
Subsequent Operational Year, Tenant's Projected Share of Operating Expenses,
which shall be payable monthly, the first payment representing the payments
retroactive to the first day of the current Operational Year and including the
current month after crediting Tenant with payments made for the current
Operational Year but made prior to the receipt of the Subsequent Operating
Statement shall be made within ten (10) days after Tenant receives a Subsequent
Operating Statement, and thereafter normal monthly payments shall be made on the
first day of each month throughout the upcoming Operational Year and thereafter
until receipt of the next Subsequent Operating Statement. If a Subsequent
Operating Statement furnished by Landlord to Tenant for a recently expired
Operational Year shall indicate that Tenant's Projected Share of Operating
Expenses exceeded Tenant's Actual Share of Operating Expenses, Landlord shall
refund the amount of excess to Tenant within ten (10) days after delivery of the
statement. If, however, the Subsequent Operating Statement shall indicate that
Tenant's Actual Share of Operating Expenses exceeded Tenant's Projected Share of
Operating Expenses, Tenant shall, within ten (10) days, pay the amount of such
excess to Landlord as additional rent.
(d) Xxxxxxxx's failure to render any statement required to be
furnished by Landlord to Tenant pursuant to this Section 5.09 shall in no way
prejudice Tenant's right to receive a refund for the overpayment of any sums
paid by Xxxxxx on account of Operating Expenses pursuant to Article 5.
5.10 The Initial Operating Statement, Second Operating Statement, and
every Subsequent Operating Statement given by Landlord shall be conclusive and
binding upon Tenant unless Tenant shall (a) notify Landlord within sixty (60)
days after its receipt of such statement that it disputes the correctness
thereof, specifying the particular respects in which the statement is claimed to
be incorrect and (b) submit its dispute to arbitration within one-hundred twenty
(120) days after its receipt of the Initial Operating Statement, Second
Operating Statement, or Subsequent Operating Statement, if such dispute shall
not theretofore be settled by agreement between Landlord and Tenant. Pending the
resolution of such dispute by agreement or arbitration as aforesaid, Tenant
shall, within ten (10) days after receipt of such disputed Initial Operating
Statement, Second Operating Statement, or Subsequent Operating Statement, as the
case may be, pay any additional rent due in accordance therewith, but such
payment shall be without prejudice to Tenant's right to dispute such statement.
If the dispute shall be resolved in Tenant's favor,
-16-
Landlord shall, within ten (10) days thereafter, pay Tenant the amount of the
overpayment, if any, resulting from Tenant's compliance with the disputed
Initial Operating Statement, Second Operating Statement or Subsequent Operating
Statement together with interest at the Agreed Rate from the date of such
overpayment. Xxxxxxxx agrees to grant Tenant reasonable access to Xxxxxxxx's
books and records for the purpose of verifying Operating Expenses incurred by
Landlord and to make copies of any and all bills and vouchers relating thereto.
5.11 Subject to the further provisions of this Section, Landlord shall be
under no obligation to contest the Taxes or the assessed valuation of the Land
and/or Building for any Tax Year, or to refrain from contesting the same, and
may settle any such contest on such terms as Landlord in its sole judgment
considers proper. If tenants of at least seventy-five (75%) percent of the total
occupied rentable area of the Building shall, by timely notice to Landlord,
request Landlord to do so, Landlord shall institute appropriate proceedings to
reduce the Taxes for any Tax Year and use its best efforts to effect a reduction
therein. If tenants of seventy-five (75%) percent of the total occupied rentable
area of the Building request Landlord to do so, then Tenant shall pay its
proportionate share (according to the relation that the rentable area of the
Demised Premises bears to the total occupied rentable area represented by all
such requesting tenants) of the reasonable costs and expenses of such
proceedings which shall have been instituted at the request of such tenants.
Landlord shall not compromise, cancel or withdraw such proceedings which shall
have been instituted at the request of tenants of seventy-five (75%) percent or
more of the total occupied rentable area unless it shall have first notified all
such requesting tenants of its proposal to do so and shall not have received,
within thirty (30) days thereafter, objections in writing from tenants of more
than fifty (50%) percent of the total occupied rentable area represented by such
requesting tenants, accompanied by written agreements to reimburse Landlord
forthwith for all of its costs and expenses in connection with the proceedings
and relieve Landlord of all of its commitments in connection therewith, for
which such objectors shall be liable ratably according to their respective
rentable areas in relation to the total rentable area represented by all such
objectors. Upon receipt of such objections, agreements and reimbursements,
Landlord shall transfer the responsibility for such proceedings to said
objectors who may carry on the same in their own names or the Landlord's name,
as may be appropriate, at their own expense and shall be entitled to recoupment
for all of their costs and expenses from any refund obtained, but not otherwise.
ARTICLE 6
Adjacent Excavation--Shoring
6.01 If an excavation or other substructure work shall be made upon land
adjacent to the Demised Premises, or shall be authorized to be made, Tenant
shall afford to the person causing or authorized to cause such excavation,
license to enter upon the Demised Premises for the purpose of doing such work as
shall be necessary to preserve the wall of or the Building from injury or damage
and to support the same by proper foundations without any claim for damages or
indemnity against Landlord, or diminution or abatement of rent.
-17-
ARTICLE 7
Subordination, Notice To Lessors And Mortgagees
7.01 This lease, and all rights of Tenant hereunder, shall be subject and
subordinate in all respects to all ground leases, overriding leases and
underlying leases relating to the Land and/or the Building to the extent that
any of the foregoing may hereafter exist and to all mortgages which may
hereafter affect the Land and/or the Building and/or any of such leases of which
the Demised Premises may be a part, to each and every advance made or hereafter
to be made under such mortgages, and to all renewals, modifications,
replacements and extensions of such leases, and such mortgages and spreaders and
consolidations of such mortgages. This Section shall be self-operative and no
further instrument of subordination shall be required. In confirmation of such
subordination, Tenant shall promptly execute and deliver any instrument that
Landlord, the lessor of any such lease or the holder of any such mortgage or any
of their respective successors in interest may reasonably request to evidence
such subordination. The leases to which this lease is, at the time referred to,
subject and subordinate pursuant to this Article are hereinafter sometimes
called "superior leases" and the mortgages to which this lease is, at the time
referred to, subject and subordinate are hereinafter sometimes called "superior
mortgages" and the lessor of a superior lease or its successor in interest at
the time referred to is sometimes hereinafter called a "lessor".
7.02 In the event of any act or omission of Landlord which would give
Tenant the right, immediately or after lapse of a period of time, to cancel or
terminate this lease, or to claim a partial or total eviction, Tenant shall not
exercise such right (i) until it has given written notice of such act or
omission to the holder of each superior mortgage and the lessor of each superior
lease whose name and address shall previously have been furnished to Tenant in
writing, and (ii) unless such act or omission shall be one which is not capable
of being remedied by Landlord or such mortgage holder or lessor within a
reasonable period of time, until a reasonable period (but not less than sixty
(60) days) for remedying such act or omission shall have elapsed following the
giving of such notice and following the time when such holder or lessor shall
have become entitled under such superior mortgage or superior lease, as the case
may be, to remedy the same (which reasonable period shall in no event be less
than the period to which Landlord would be entitled under this lease or
otherwise, after similar notice, to effect such remedy), provided such holder or
lessor shall with due diligence give Tenant written notice of intention to, and
commence and continue to remedy such act or omission.
7.03 The subordination of this lease to ground, overriding or underlying
leases in accordance with Section 7.01 is subject to the express condition that
so long as this lease shall be in effect in the event of termination of the term
of any such ground, overriding or underlying lease by reentry, notice, summary
proceedings or other action or proceeding or if the term of such ground,
overriding or underlying lease shall otherwise terminate or expire before the
termination or expiration of the term of this lease, Tenant shall not be made a
party to any action or proceeding to remove or evict Tenant or to disturb its
possession by reason of or based upon such termination or expiration of the term
of such ground, overriding or underlying lease, and this lease shall continue in
full force and effect as a direct lease between Tenant and the the owner of the
fee or lessor of such ground, overriding or underlying lease, as the case may
be, upon all of the obligations of this lease, except that other than the
payment of Landlord's Share under Exhibit C, if said
-18-
owner or lessor is not Landlord or a related entity of Landlord, said owner or
lessor shall not (i) be subject to any offsets or defenses against or be liable
for any previous act or omission of any prior landlord (including Landlord)
under this lease (ii) be bound by any modification of this lease made without
its consent where Tenant prior to such modification shall have either received
notice of such ground, overriding or underlying lease or such ground, overriding
or underlying lease or a memorandum thereof shall have been of record, or (iii)
be bound by any prepayment of more than one month's rent.
7.04 The subordination of this lease to the liens of mortgages in
accordance with Section 7.01 is subject to the express condition that so long as
this lease shall be in effect, (a) Tenant shall not be named or joined in any
action or proceeding to foreclose any such mortgage, (b) such action or
proceeding shall not result in a cancellation or termination of the term of this
lease, and (c) if the holder of any such mortgage becomes the owner of the fee
or the assignee of any ground or underlying lease referred to in Section 7.01,
or the lessee of any other lease given in substitution therefor, or if the Land
or the Building shall be sold as a result of any action or proceeding to
foreclose such mortgage, this lease shall continue in full force and effect as a
direct lease between Tenant and the then owner of the fee or the then lessee of
such ground, overriding or underlying lease, or the lessee of any other lease
given in substitution therefor, or such purchaser of the Land or Building, as
the case may be, upon all of the obligations of this lease, except that other
than the payment of Landlord's Share under Exhibit C, if such owner, lessee or
purchaser is not Landlord or a related entity of Landlord, such owner, lessor or
purchaser shall not (i) be bound by any prepayment of more than one month's
rent, or (ii) be bound by any modification of this lease made without the
consent of the holder of the mortgage (where Xxxxxx shall have received notice
of such mortgage prior to such modification), be subject to any offsets or
defenses against or be liable for any previous act or omission of any prior
landlord (including Landlord) under this lease except as hereinafter provided in
this Section 7.04, or (iv) be liable for performance of any initial work or
installations which are required to be made by Landlord hereunder other than the
payment of Landlord's Share under Exhibit C.
7.05 Landlord represents that as of the date hereof there are no superior
leases and superior mortgages except as listed on Exhibit F annexed hereto.
ARTICLE 8
Quiet Enjoyment
8.01 Provided no Event of Default shall have occurred and is continuing,
Tenant may peaceably and quietly enjoy the Premises, subject to the terms and
conditions of this Lease.
ARTICLE 9
Assignment And Subletting
9.01 Tenant, for itself, its heirs, distributees, executors,
administrators, legal representatives, successors and assigns, expressly
covenants that, except as expressly provided in this lease, it shall not assign,
mortgage or encumber this agreement, nor
-19-
underlet, nor suffer, nor permit the Demised Premises or any part thereof to be
used or occupied by others, without the prior written consent of Landlord in
each instance. If this lease be assigned, or if the Demised Premises or any part
thereof be underlet or occupied by anybody other than Tenant, Landlord may,
after default by Tenant, collect rent from the assignee, undertenant or
occupant, and apply the net amount collected to the rent herein reserved, but no
assignment, underletting, occupancy or collection shall be deemed a waiver of
the provisions hereof, the acceptance of the assignee, undertenant or occupant
as tenant, or a release of Tenant from the further performance by Tenant of
covenants on the part of Tenant herein contained. The consent by Landlord to an
assignment or underletting shall not in any wise be construed to relieve Xxxxxx
from obtaining the express consent in writing of Landlord to any further
assignment or underletting. In no event shall any permitted sublessee assign or
encumber its sublease or further sublet all or any portion of its sublet space,
or otherwise suffer or permit the sublet space or any part thereof to be used or
occupied by others, without Landlord's prior written consent in each instance.
9.02 If Tenant shall at any time or times during the term of this lease
desire to assign this lease or sublet all or part of the Demised Premises,
Tenant shall send written notice (hereinafter referred to as a "Sublease
Notice") to Landlord, which Sublease Notice shall specify: (i) the expected
effective or commencement date of such proposed assignment or sublet, as the
case may be, (ii) a description of the portion of the Demised Premises to be
sublet (in the case of a proposed sublease) and (iii) the terms ("Tenant's
Terms") upon which Xxxxxx is willing to enter into such assignment or sublease.
Such Sublease Notice shall be deemed an offer from Tenant to Landlord whereby
Landlord (or Landlord's designee) may, at its option, (w) accept such assignment
(if the Sublease Notice refers to assignment) (x) sublease such space
(hereinafter called the "Leaseback Space") from Tenant upon the terms and
conditions hereinafter set forth (if the proposed transaction is a sublease of
all or part of the Demised Premises), (y) terminate this lease (if the proposed
transaction is an assignment or a sublease of all or substantially all of the
Demised Premises), or (z) terminate this lease with respect to the Leaseback
Space (if the proposed transaction is a sublease of part of the Demised Premises
and the term of such sublease ends less than two (2) years prior to the
Expiration Date). If Landlord shall desire to exercise any of the aforesaid
options, Landlord shall send Tenant written notice thereof (hereinafter referred
to as a "Landlord Acceptance Notice") on or before the thirtieth (30th) day next
succeeding the day upon which Tenant shall have sent the Sublease Notice to
Landlord and during such 30-day period Tenant shall not assign this lease nor
sublet such space to any person. If Tenant intends to revise the Tenant's Terms
to make them more favorable to other parties, Tenant shall notify Landlord of
the revisions which are more favorable ("Revised Tenant's Terms"), and Landlord
shall have an additional period of ten (10) days after receipt of the Revised
Tenant's Terms within which to send a Landlord's Acceptance Notice. If Landlord
shall fail to notify Tenant within the time periods prescribed above of
Landlord's intention to exercise its rights pursuant to this Section 9.02 or if
Landlord shall have consented to such assignment or subletting as provided in
Section 9.07, Tenant shall be free to assign its interest in this lease or
sublease that portion of the Demised Premises to such proposed subtenant on the
same material terms and conditions set forth in the Sublease Notice, subject to
the terms and conditions set forth in Section 9.09 hereof.
9.03 If Landlord exercises its option to terminate this lease in the case
where Tenant desires either to assign this lease or sublet all or substantially
all of the Demised
-20-
Premises, then, this lease shall end and expire on the date that such assignment
or sublet was to be effective or commence, as the case may be, and the fixed
rent and additional rent shall be paid and apportioned to such date.
9.04 If Landlord exercises its option to terminate this lease in part in
any case where Tenant desires to sublet part of the Demised Premises, then, (a)
this lease shall end and expire with respect to such part of the Demised
Premises on the date that the proposed sublease was to commence; (b) from and
after such date the fixed rent and additional rent shall be adjusted, based upon
the proportion that the rentable area of the Demised Premises remaining bears to
the total rentable area of the Demised Premises; and (c) Landlord shall make
such alterations as may be reasonably required to physically separate such part
of the Demised Premises from the balance of the Demised Premises, in compliance
with any laws and requirements of any public authorities relating to such
separation, at the expense of such party as shall have been designated in the
Sublease Notice.
9.05 If Landlord shall send a Landlord's Acceptance Notice to Tenant in
the case of Landlord's exercise of its option as set forth in Subdivision (x) of
Section 9.02 in the form and manner, and within the thirty (30) day period
referred to in Section 9.02 hereof, the parties hereto shall promptly enter into
a new sublease (hereinafter referred to as the "Recapture Sublease") for the
Recapture Space, which Recapture Sublease shall:
(a) be on the same terms and conditions contained in this lease (as
modified by the Sublease Notice), except such as are irrelevant or inapplicable
and except as otherwise expressly set forth to the contrary in this Section;
(b) provide for a rental at the lower of (i) the rental rate per
rentable square foot of fixed rent and additional rent then payable pursuant to
this lease or (ii) the rentals set forth in the Sublease Notice and shall be for
the same term as that set forth in the Sublease Notice;
(c) be expressly subject to all of the covenants, agreements, terms,
provisions and conditions of this lease except such as are irrelevant or
inapplicable, and except as otherwise expressly set forth to the contrary in
this Section;
(d) give the sublessee the unqualified and unrestricted right,
without Xxxxxx's permission, to assign such sublease or any interest therein
and/or to sublet the Leaseback Space or any part or parts of the Leaseback Space
to any entity other than a firm the primary business of which is the sale or
trading of securities and to make any and all changes, alterations, and
improvements in the space covered by such sublease;
(e) provide that any assignee or further subtenant, of Landlord or
its designee, may, at the election of Landlord, be permitted to make
alterations, decorations and installations in the Leaseback Space or any part
thereof and shall also provide in substance that any such alterations,
decorations and installations in the Leaseback Space therein made by any
assignee or subtenant of Landlord or its designee may be removed, in whole or in
part, by such assignee or subtenant, at its option, prior to or upon the
expiration or other termination of such sublease provided that such assignee or
subtenant, at its expense, shall repair any damage and injury caused thereby;
and
-21-
(f) provide that (i) the parties to such sublease expressly negate
any intention that any estate created under such sublease be merged with any
other estate held by either of said parties, (ii) any assignment or subletting
by Landlord or its designee (as the subtenant) may be for any purpose or
purposes that Landlord, in Landlord's uncontrolled discretion, shall deem
suitable or appropriate, (iii) Tenant, at Tenant's expense, shall and will at
all times provide and permit reasonably appropriate means of ingress to and
egress from the Leaseback Space so sublet by Tenant to Landlord or its designee,
(iv) Landlord, at Tenant's expense (unless otherwise specified in the Sublease
Notice), may make such alterations as may be required or deemed necessary by
Landlord to physically separate the Leaseback Space from the balance of the
Demised Premises and to comply with any laws and requirements of public
authorities relating to such separation, and (v) that at the expiration of the
term of such sublease, Tenant will accept the space covered by such sublease in
its then existing condition and broom clean, subject to the obligations of the
sublessee to make such repairs thereto as may be necessary to preserve the
premises demised by such sublease in good order and condition.
9.06 (a) If Landlord exercises its option to sublet the Leaseback Space,
Landlord shall indemnify and save Tenant harmless from all obligations under
this lease (except payment of rental) as to the Leaseback Space during the
period of time it is so sublet to Landlord.
(b) Performance by Landlord, or its designee, under a Recapture
Sublease shall be deemed performance by Tenant of any similar obligation under
this lease and any default under any such sublease shall not give rise to a
default under a similar obligation contained in this Lease, nor shall Tenant be
liable for any default under this lease or deemed to be in default hereunder if
such default is occasioned by or arises from any act or omission of the
subtenant under the Recapture Sublease or is occasioned by or arises from any
act or omission of any occupant holding under or pursuant to any such sublease.
(c) Tenant shall have no obligation, at the expiration or earlier
termination of the term of this lease, to remove any alteration, installation or
improvement made in the Leaseback Space by Landlord or its designee.
9.07 Notwithstanding the provisions of Section 9.01 hereof, in the event
Landlord does not exercise an option provided to it pursuant to Section 9.02 and
providing that Tenant is not in default of any of Tenant's obligations under
this lease after notice and the expiration of any applicable grace period,
Xxxxxxxx's consent (which must be in writing and in form reasonably satisfactory
to Landlord) to the proposed assignment or sublease shall not be unreasonably
withheld or delayed, provided and upon condition that:
(a) Tenant shall have complied with the provisions of Section 9.02
within the time permitted therefor;
(b) In Landlord's reasonable judgment the proposed assignee or
subtenant is engaged in a business and the Demised Premises, or the relevant
part thereof, will be used in a manner which (i) is in keeping with the then
standards of the Building, (ii) is limited to the use expressly permitted under
this lease, and (iii) will not violate any negative covenant as to use contained
in any other lease of space in the Building;
-22-
(c) The proposed assignee or sublessee is not then an occupant of
any part of the Building;
(d) The proposed assignee or sublessee is not a person with whom
Landlord is then negotiating to lease space in the Building; if Tenant shall
propose to sublease space or assign its interest in this lease and is about to
commence negotiations with a prospective assignee or subtenant, Tenant shall
advise Landlord of the identity of such prospective assignee or subtenant and
Landlord shall, within ten (10) days thereafter, advise Tenant if the execution
of an assignment or sublease with such prospective assignee or subtenant, as the
case may be, would violate the provisions of this subsection (d);
(e) The form of the proposed sublease shall be in form reasonably
satisfactory to Landlord and shall comply with the applicable provisions of this
Article;
(f) There shall not be more than 3 subtenants (including Landlord or
its designee) on any one (1) floor of the Demised Premises;
(g) Tenant shall have used its good faith efforts to rent the
Leaseback Space at the then current market rent per rentable square foot for the
Demised Premises as though the Demised Premises were vacant, and the rental and
other material terms and conditions of the sublease are not more favorable to
the proposed subtenant than those contained in the Sublease Notice furnished to
Landlord pursuant to Section 9.02 hereof;
(h) Tenant shall reimburse Landlord on demand for any reasonable
costs that may be incurred by Landlord in connection with said assignment or
sublease, including, without limitation, the costs of making investigations as
to the acceptability of the proposed assignee or subtenant, and reasonable legal
costs incurred in connection with the granting of any requested consent;
(i) The Demised Premises shall not, without Landlord's prior
consent, have been listed or otherwise publicly advertised for subletting at a
rental rate less than the greater of (1) the fixed rent and additional rent then
payable hereunder for such space, or (2) the fixed rent and additional rent at
which Landlord is then offering to lease other space in the Building, nor shall
any advertisement state the name (as distinguished from the address) of the
Building;
(j) Except as may be specifically permitted by this lease, the
sublease shall not allow the use of the Demised Premises or any part thereof for
the preparation and/or sale of food for on or off premises consumption;
(k) The sublease shall not allow the Demised Premises or any part
thereof to be used by any foreign or domestic governmental agency; and
(1) Unless Landlord shall notify Tenant that it denies its consent
to the proposed assignment or sublease on or before the twentieth (20th) day
after the conditions contained in this Section 9.07 have been complied with,
then Landlord shall be deemed to have consented to the proposed assignment or
subletting.
-23-
Except for any Recapture Sublease, each subletting pursuant to this
Article 9 shall be subject to all of the covenants, agreements, terms,
provisions and conditions contained in this lease. Notwithstanding any such
subletting to Landlord or any such subletting to any other subtenant and/or
acceptance of rent or additional rent by Landlord from any subtenant, Tenant
shall and will remain fully liable for the payment of the fixed rent and
additional rent due and to become due hereunder and for the performance of all
the covenants, agreements, terms, provisions and conditions contained in this
lease on the part of Tenant to be performed and all acts and omissions of any
licensee or subtenant or anyone claiming under or through any subtenant which
shall be in violation of any of the obligations of this lease, and any such
violation shall be deemed to be a violation by Tenant. Xxxxxx further agrees
that notwithstanding any such subletting, no other and further subletting of the
Demised Premises by Tenant or any person claiming through or under Tenant
(except as provided in Section 9.05) shall or will be made except upon
compliance with and subject to the provisions of this Article. If Landlord shall
decline to give its consent to any proposed assignment or sublease, or if
Landlord shall exercise any of its options under Section 9.02, Tenant shall
indemnify, defend and hold harmless Landlord against and from any and all loss,
liability, damages, costs and expenses (including reasonable counsel fees)
resulting from any claims that may be made against Landlord by the proposed
assignee or sublessee or by any brokers or other persons not engaged by Landlord
claiming a commission or similar compensation in connection with the proposed
assignment or sublease.
9.08 In the event that (a) Landlord fails to exercise any of its options
under Section 9.02 and consents to a proposed assignment or sublease, and (b)
Tenant fails to execute and deliver the assignment or sublease to which Landlord
consented within 120 days after the giving of such consent, then, Tenant shall
again comply with all of the provisions and conditions of Section 9.02 before
assigning this lease or subletting all or part of the Demised Premises.
9.09 With respect to each and every sublease or subletting authorized by
Landlord under the provisions of this lease, it is further agreed:
(a) no subletting shall be for a term ending later than one day
prior to the expiration date of this lease;
(b) no sublease shall be valid, and no subtenant shall take
possession of the Demised Premises or any part thereof, until an executed
counterpart of such sublease has been delivered to Landlord; and
(c) each sublease shall provide that it is subject and subordinate
to this lease and to the matters to which this lease is or shall be subordinate,
and that in the event of termination, re-entry or dispossess by Landlord under
this lease Landlord may, at its option, take over all of the right, title and
interest of Tenant, as sublessor, under such sublease, and such subtenant shall,
at Landlord's option, attorn to Landlord pursuant to the then executory
provisions of such sublease, except that Landlord shall not (i) be liable for
any previous act or omission of Tenant under such sublease, (ii) be subject to
any offset, not expressly provided in such sublease, which theretofore accrued
to such subtenant against Tenant, or (iii) be bound by any previous modification
of such sublease (unless Landlord shall have consented thereto) or by any
previous prepayment of more than one month's rent.
-24-
9.10 If Tenant shall sublet any "Free Sublet Space" (as defined in Section
9.13), or if the Landlord shall give its consent to any assignment of this lease
or to any sublease, or permits the occupancy, of all or any part of the Demised
Premises other than the "10th Floor Space" for any period of time prior to the
"Effective Date" (as such quoted terms are defined in Section 41.01), or if
Landlord shall give its consent to any sublease of all or any part of the 10th
Floor Space for any period of time after the Effective Date (collectively,
"Tenant's Disposition"), Tenant shall pay Landlord, on the first day of each
month during the term of the Tenant's Disposition, fifty (50%) percent of the
amount by which (1) the fixed rent and tax and expense escalation payments, and
any other amounts, due under such Tenant's Disposition which are received by
Tenant during the preceding month, exceeds (2) that portion of the fixed rent
and amounts due pursuant to Article 5 hereof and other payments due from Tenant
hereunder which is attributable to the space covered by the Tenant's
Disposition, for such preceding month. There shall first be deducted from any
payments otherwise due to Landlord pursuant to this Section 9.10 the following
reasonable expenses incurred by the Tenant in connection with the applicable
Tenant's Disposition: (i) a customary brokerage commission, (ii) attorney's
fees, (iii) out-of-pocket advertising costs, (iv) the cost of renovation work
incurred by Tenant on behalf of the subtenant or assignee, (v) any payments
required to be made by Tenant pursuant to any real property transfer tax (or
similar tax) of the United States or the City of Jersey City or State of New
Jersey (other than any income tax) in connection with the transfer of all or
part of Tenant's interest in and to the Demised Premises, (vi) any sums paid by
Tenant to Landlord pursuant to Section 9.07(h), (vii) the unamortized
unreimbursed cost of any Tenant's Property (as hereinafter defined) leased to
any assignee, subtenant or occupant, and (viii) the cost of demising the space
and creating any corridors required under applicable law in order to provide
access to the space covered by Xxxxxx's Disposition. In addition, if Xxxxxx
receives any other net consideration for such Tenant's Disposition (including
monies received for Tenant's fixtures, furniture or equipment), Tenant shall pay
Landlord fifty (50%) percent of the amount of such consideration within ten (10)
days after Xxxxxx's receipt thereof (which net consideration shall be computed
in the same fashion as above provided for the computation of the net
consideration received by Tenant from a Tenant's Disposition which is a
sublease).
9.11 If Tenant is a corporation, the provisions of Section 9.01 shall
apply to a transfer (by one or more transfers) of a majority of the stock of
Tenant as if such transfer of a majority of the stock of Tenant were an
assignment of this lease; but said provisions shall not apply (i) to
transactions with a corporation into or with which Tenant is merged or
consolidated or to which substantially all of Tenant's assets are transferred or
to any corporation which controls or is controlled by Tenant or is under common
control with Tenant, provided that in any of such events (x) the successor to
Tenant has a net worth computed in accordance with generally accepted accounting
principles at least equal to the net worth of Tenant immediately prior to such
merger, consolidation or transfer, and (y) proof satisfactory to Landlord of
such net worth shall have been delivered to Landlord within ten (10) days after
the effective date of such transaction or (ii) to Tenant if its shares shall be
traded on the "over-the-counter market" or through any recognized stock
exchange.
9.12 Any assignment or transfer, whether made with Landlord's consent
pursuant to Section 9.01 or without Landlord's consent pursuant to Section 9.11,
shall be made only if, and shall not be effective until, the assignee shall
execute, acknowledge and deliver to Landlord an agreement in form and substance
satisfactory to Landlord whereby the
-25-
assignee shall assume the obligations of this lease on the part of Tenant to be
performed or observed and whereby the assignee shall agree that the provisions
in Section 9.01 shall, notwithstanding such assignment or transfer, continue to
be binding upon it in respect of all future assignments and transfers. The
original named Tenant covenants that, notwithstanding any assignment or
transfer, whether or not in violation of the provisions of this lease, and
notwithstanding the acceptance of fixed rent and/or additional rent by Landlord
from an assignee, transferee, or any other party, the original named Tenant
shall remain fully liable for the payment of the fixed rent and additional rent
and for the other obligations of this lease on the part of Tenant to be
performed or observed.
9.13 The provisions of Sections 9.02, 9.03, 9.04, 9.05, and 9.06 shall not
apply to any subletting(s) of not more than an aggregate of 37,000 square feet
of space ("Free Sublet Space") in the Demised Premises. In the event that
Landlord shall put additional space to Tenant pursuant to Section 41.05 hereof
or Tenant leases the 11th Floor as provided in Section 42.01(b), then the Free
Sublet Space shall be correspondingly increased.
9.14 The provisions of Sections 9.02, 9.03, 9.04, 9.05, 9.06, 9.07, 9.08
and 9.10 shall not apply to any subletting(s) to or occupancy of all or a
portion of the Demised Premises to any corporation which controls or is
controlled by Tenant or is under common control with Tenant or results from a
merger or consolidation with Tenant (collectively "Permitted Occupant"),
provided, however, that any subletting to or occupancy by any of the Permitted
Occupants shall be subject to and in accordance with all of the terms, covenants
and conditions of this lease.
9.15 The joint and several liability of Tenant and any immediate or remote
successor in interest of Tenant and the due performance of the obligations of
this lease on Tenant's part to be performed or observed shall not be discharged,
released or impaired in any respect by any agreement or stipulation made by
Landlord extending the time of, or modifying any of the obligations of, this
lease, or by any waiver or failure of Landlord to enforce any of the obligations
of this lease.
9.16 The listing of any name other than that of Tenant, whether on the
doors of the Premises or the Building directory, or otherwise, shall not operate
to vest any right or interest in this lease or in the Premises, nor shall it be
deemed to be the consent of Landlord to any assignment or transfer of this lease
or to any sublease of the Premises or to the use or occupancy thereof by others.
Notwithstanding the foregoing, Tenant may designate a portion of its directory
space for use by any assignee or subtenant of Tenant.
9.17 Anything contained in the foregoing provisions of this section to the
contrary notwithstanding, neither Tenant nor any other person having an interest
in the possession, use, occupancy or utilization of the Premises shall enter
into any lease, sublease, license, concession or other agreement for use,
occupancy or utilization of space in the Premises which provides for rental or
other payment for such use, occupancy or utilization based, in whole or in part,
on the net income or profits derived by any person from the premises leased,
used, occupied or utilized (other than an amount based on a fixed percentage or
percentages of receipts or sales), and any such purported lease, sublease,
license, concession or other agreement shall be absolutely void and ineffective
as a conveyance of any right or interest in the possession, use, occupancy or
utilization of any part of the Premises.
-26-
ARTICLE 10
Compliance With Laws And Requirements Of Public Authorities
10.01 Tenant shall give prompt notice to Landlord of any notice it
receives of the violation of any law or requirement of public authority, and at
its expense shall comply with all laws and requirements of public authorities
which shall, with respect to the Demised Premises or the use and occupation
thereof, or the abatement of any nuisance, impose any violation, order or duty
on Landlord or Tenant, arising from (i) the manner of conduct of Tenant's
business or operation of its installations, equipment or other property therein,
(ii) any cause or condition created by or at the instance of Tenant, other than
by Xxxxxxxx's performance of any work for or on behalf of Tenant, or (iii)
breach of any of Tenant's obligations hereunder. Furthermore, Tenant need not
comply with any such law or requirement of public authority so long as Tenant
shall be contesting the validity thereof, or the applicability thereof to the
Demised Premises, in accordance with Section 10.02. Landlord, at its expense,
shall comply with all other such laws and requirements of public authorities as
shall affect the Demised Premises, but may similarly contest the same subject to
conditions reciprocal to Subsections (a), (b) and (d) of Section 10.02.
10.02 Tenant may, at its expense (and if necessary, in the name of but
without expense to Landlord) contest, by appropriate proceedings prosecuted
diligently and in good faith, the validity, or applicability to the Demised
Premises, of any law or requirement of public authority, and Landlord shall
cooperate with Tenant in such proceedings, provided that:
(a) Landlord shall not be subject to criminal penalty or to
prosecution for a crime nor shall the Demised Premises or any part thereof be
subject to being condemned or vacated, by reason of non-compliance or otherwise
by reason of such contest;
(b) Tenant shall defend, indemnify and hold harmless Landlord
against all liability, loss or damage which Landlord shall suffer by reason of
such non-compliance or contest, including reasonable attorney's fees and other
expenses reasonably incurred by Landlord and shall post with Landlord a surety
bond or other security reasonably satisfactory to Landlord prior to the
commencement of any contest;
(c) Such non-compliance or contest shall not constitute or result in
any violation of any superior lease or superior mortgage, or if such superior
lease and/or superior mortgage shall permit such non-compliance or contest on
condition of the taking of action or furnishing of security by Landlord, such
action shall be taken and such security shall be furnished at the expense of
Tenant; and
(d) Tenant shall keep Landlord advised as to the status of such
proceedings.
Without limiting the application of Subsection (a) above thereto, Landlord shall
be deemed subject to prosecution for a crime within the meaning of said
Subsection, if Landlord, or any officer of Landlord individually, is charged
with a crime of any kind or degree whatever, whether by service of a summons or
otherwise, unless such charge is withdrawn before Landlord or such officer (as
the case may be) is required to plead or answer thereto.
-27-
ARTICLE 11
Insurance
11.01 Tenant shall not violate, or permit the violation of, any condition
imposed by the standard fire insurance policy then issued for office buildings
in the City of Jersey City, and shall not do, or permit anything to be done, or
keep or permit anything to be kept in the Demised Premises which would subject
Landlord to any liability or responsibility for personal injury or death or
property damage, or which would increase the fire or other casualty insurance
rate on the Building or the property therein over the rate which would otherwise
then be in effect (unless Tenant pays the resulting premium as provided in
Section 11.03) or which would result in insurance companies of good standing
refusing to insure the Building or any of such property in amounts reasonably
satisfactory to Landlord.
11.02 Tenant covenants to provide on or before the Commencement Date and
to keep in force during the term hereof the following insurance coverage:
(a) For the the benefit of Landlord and Tenant a comprehensive
policy of liability insurance protecting Landlord and Tenant against any
liability whatsoever occasioned by accident on or about the Demised Premises or
any appurtenances thereto. Such policy is to be written by good and solvent
insurance companies authorized to do business in the State of New Jersey and the
limits of liability thereunder shall not be less than the amount of Four Million
($4,000,000.00) Dollars combined single limit coverage for property damage and
bodily injury on a per occurrence basis. Such insurance may be carried under a
blanket policy covering the Demised Premises and other locations of Tenant, if
any.
(b) Fire and Extended coverage in an amount adequate to cover the
cost of replacement of all personal property, fixtures, furnishing and
equipment, including Xxxxxx's Work located in the Demised Premises. Such policy
shall be written by good and solvent insurance companies authorized to do
business in the State of New Jersey.
Prior to the time such insurance is first required to be carried by
Xxxxxx and thereafter, at least fifteen (15) days prior to the expiration of any
such policies, Xxxxxx agrees to deliver to Landlord either duplicate originals
of the aforesaid policies or certificates evidencing such insurance, provided
said certificate contains an endorsement that such insurance may not be modified
or cancelled except upon fifteen (15) days' notice to Landlord, together with
evidence of payment for the policy. Tenant's failure to provide and keep in
force the aforementioned insurance shall be regarded as a material default
hereunder, entitling Landlord to exercise any or all of the remedies as provided
in this lease in the event of Tenant's default.
-28-
11.03 Landlord and Tenant shall each endeavor to secure an appropriate
clause in, or an endorsement upon, each fire or extended coverage policy
obtained by it and covering the Building, the Demised Premises or the personal
property, fixtures and equipment located therein or thereon, pursuant to which
the respective insurance companies waive subrogation or permit the insured,
prior to any loss, to agree with a third party to waive any claim it might have
against said third party. The waiver of subrogation or permission for waiver of
any claim hereinbefore referred to shall extend to the agents of each party and
its employees and, in the case of Tenant, shall also extend to all other persons
and entities occupying or using the Demised Premises in accordance with the
terms of this lease. If and to the extent that such waiver or permission can be
obtained only upon payment of an additional charge then, except as provided in
the following two paragraphs, the party benefiting from the waiver or permission
shall pay such charge upon demand, or shall be deemed to have agreed that the
party obtaining the insurance coverage in question shall be free of any further
obligations under the provisions hereof relating to such waiver or permission.
In the event that Landlord shall be unable at any time to obtain one of
the provisions referred to above in any of its insurance policies, at Tenant's
option Landlord shall cause Tenant to be named in such policy or policies as one
of the assureds, but if any additional premium shall be imposed for the
inclusion of Tenant as such as assured, Tenant shall pay such additional premium
upon demand. In the event that Tenant shall have been named as one of the
assureds in any of Landlord's policies in accordance with the foregoing, Tenant
shall endorse promptly to the order of Landlord, without recourse, any check,
draft or order for the payment of money representing the proceeds of any such
policy or any other payment growing out of or connected with said policy and
Tenant hereby irrevocably waives any and all rights in and to such proceeds and
payments.
In the event that Tenant shall be unable at any time to obtain one of the
provisions referred to above in any of its insurance policies, Tenant shall
cause Landlord to be named in such policy or policies as one of the assureds,
but if any additional premium shall be imposed for the inclusion of Landlord as
such an assured, Landlord shall pay such additional premium upon demand or
Tenant shall be excused from its obligations under this paragraph with respect
to the insurance policy or policies for which such additional premiums would be
imposed. In the event that Landlord shall have been named as one of the assureds
in any of Tenant's policies in accordance with the foregoing, Landlord shall
endorse promptly to the order of Tenant, without recourse, any check, draft or
order for the payment of money representing the proceeds of any such policy or
any other payment growing out of or connected with said policy and Landlord
hereby irrevocably waives any and all rights in and to such proceeds and
payments.
Subject to the foregoing provisions of this Section 11.03, and insofar as
may be permitted by the terms of the insurance policies carried by it, each
party hereby releases the other with respect to any claim (including a claim for
negligence) which it might otherwise have against the other party for loss,
damages or destruction with respect to its property by fire or other casualty
(including rental value or business interruption, as the case may be) occurring
during the term of this lease.
11.04 If, by reason of a failure of Tenant to comply with the provisions
of Section 10.01 or Section 11.01, the rate of fire insurance with extended
coverage on the Building or equipment or other property of Landlord shall be
higher than it otherwise would be,
-29-
Tenant shall reimburse Landlord, on demand, for that part of the premiums for
fire insurance and extended coverage paid by Landlord because of such failure on
the part of Tenant.
11.05 If any dispute shall arise between Landlord and Tenant with respect
to the incurrence or amount of any additional insurance premium referred to in
Section 11.01 or 11.03, the dispute shall be determined by arbitration.
11.06 A schedule or make up of rates for the Building or the Demised
Premises, as the case may be, issued by the New Jersey Fire Insurance Rating
Organization or other similar body making rates for fire insurance and extended
coverage for the premises concerned, shall be conclusive evidence of the facts
therein stated and of the several items and charges in the fire insurance rate
with extended coverage then applicable to such premises.
11.07 Landlord agrees that so long as a first mortgage on the Building is
held by an institutional lender, it will carry such casualty insurance as may be
required by the holder of such mortgage. In the event that there shall be no
first mortgage held by an institutional lender, then and in such event Landlord
shall carry such casualty insurance as is normally and customarily carried by
owners of similar buildings in the vicinity of the Building. As used in this
Section 11.07, the term "institutional lender" shall mean a savings bank, a
savings and loan association, a commercial bank or trust company (whether acting
individually or in a fiduciary trust capacity), an insurance company organized
and existing under the laws of the United States or any state thereof, a real
estate investment trust, a union, federal, state, municipal or secular
employee's welfare, benefit, pension or retirement fund or any combination of
institutional lenders, in each case having total assets or endowment of not less
than $500,000,000 and generally referred to and acknowledged in the New York
City real estate industry to be an "institutional lender" or institutional
investor."
ARTICLE 12
Rules And Regulations
12.01 Tenant and its employees and agents shall faithfully observe and
comply with the Rules and Regulations annexed hereto as Exhibit D, and such
reasonable changes therein (whether by modification, elimination or addition) as
Landlord at any time or times hereafter may make and communicate in writing to
Tenant, which do not unreasonably affect the conduct of Xxxxxx's business in the
Demised Premises except as required by any governmental law, rule, regulation,
ordinance or similar decree; provided, however, that in case of any conflict or
inconsistency between the provisions of this lease and any of the Rules and
Regulations as originally promulgated or as changed, the provisions of this
lease shall control.
12.02 Nothing in this lease contained shall be construed to impose upon
Landlord any duty or obligation to Tenant to enforce the Rules and Regulations
or the terms, covenants or conditions in any other lease, as against any other
tenant, and Landlord shall not be liable to Tenant for violation of the same by
any other tenant or its employees, agents or visitors. However, Landlord shall
not enforce any of the Rules and Regulations in such manner as to discriminate
against Tenant or anyone claiming under or through
-30-
Tenant. In the event Landlord refuses to enforce any Rules and Regulations
against an offending tenant, Landlord agrees that Xxxxxx, in Xxxxxxxx's name but
at Xxxxxx's sole cost and expense may seek to enforce Landlord's rights against
the offending tenant.
ARTICLE 13
Tenant's Changes
13.01 Tenant may from time to time during the term of this lease, at its
expense, make such alterations, additions, installations, substitutions,
improvements and decorations (hereinafter collectively called "changes" and, as
applied to changes provided for in this Article, "Tenant's Changes") in and to
the Demised Premises, excluding structural changes, as Tenant may reasonably
consider necessary or desirable for the conduct of its business in the Demised
Premises, on the following conditions:
(a) The outside appearance or the strength of the Building or of any
of its structural parts shall not be affected.
(b) No part of the Building outside of the Demised Premises shall be
physically affected.
(c) The proper functioning of any of the mechanical, electrical,
sanitary and other service systems of the Building shall not be adversely
affected or the usage of such systems by Tenant shall not be materially
increased.
(d) In performing the work involved in making such changes, Tenant
shall use contractors reasonably acceptable to Landlord and Tenant shall be
bound by and observe all of the conditions and covenants contained in the
following Sections of this Article.
(e) Before proceeding with any change the cost of which will exceed
$100,000 (exclusive of the costs of decorating work and items constituting
"Tenant's Property", as defined in Article 14, and of any architect's and
engineer's fees), or any change to the mechanical, electrical, sanitary, and/or
other service systems, Tenant shall submit to Landlord plans and specifications
for the work to be done and the names of the contractors who will perform the
work, all for Landlord's approval not to be unreasonably withheld or delayed. If
Landlord shall fail to disapprove Tenant's plans and specifications within ten
(10) business days after Xxxxxxxx's receipt thereof, Landlord shall be deemed to
have approved such plans and specifications. Any disapproval given by Landlord
shall be ineffective unless accompanied by a statement in reasonable specificity
of the reasons for such disapproval. Landlord may as a condition of its consent
require Tenant to make revisions in and to the plans and specifications and if
the cost of the changes exceed $500,000 in the aggregate to post a bond or other
security reasonably satisfactory to Landlord to insure the completion of such
change. The provisions of this Section 13.01 shall not be applicable to initial
installations which shall be governed by the provisions of Exhibit C annexed
hereto.
13.02 Tenant, at its expense, shall obtain all necessary governmental
permits and certificates for the commencement and prosecution of Xxxxxx's
Changes and for final
-31-
approval thereof upon completion, and shall cause Tenant's Changes to be
performed in compliance therewith and with all applicable laws and requirements
of public authorities, and with all applicable requirements of insurance bodies,
and in good and workmanlike manner, using materials and equipment at least equal
in quality and class to the original installations in the Building. Tenant's
Changes shall be performed in such manner as not to unreasonably interfere with
or delay and (unless Tenant shall indemnify Landlord therefor to the latter's
reasonable satisfaction) as not to impose any additional expense upon Landlord
in the construction, maintenance or operation of the Building. Throughout the
performance of Tenant's Changes, Tenant, at its expense, shall carry, or cause
to be carried, workmen's compensation insurance in statutory limits and general
liability insurance for any occurrence in or about the Building as set forth in
Section 11.02 hereof, in which Landlord and its agents shall be named as parties
insured, in such limits as Landlord may reasonably prescribe, with good and
solvent insurance companies authorized to do business in the State of New
Jersey. Tenant shall furnish Landlord with satisfactory evidence that such
insurance is in effect at or before the commencement of Tenant's Changes and, on
request, at reasonable intervals thereafter during the continuance of Tenant's
Changes. If any of Tenant's Changes shall involve the removal of any fixtures,
equipment or other property in the Demised Premises which are not Tenant's
Property (as defined in Article 14), such fixtures, equipment or other property
shall be promptly replaced, at Tenant's expense, with fixtures, equipment or
other property (as the case may be) of like utility and at least equal value
unless Landlord shall otherwise expressly consent in writing and Tenant shall,
upon Landlord's request, store and preserve, at Tenant's sole cost and expense,
any such fixtures, equipment or property so removed and shall return same to
Landlord upon the expiration or sooner termination of this lease. All electrical
and plumbing work in connection with Xxxxxx's changes shall be performed by
contractors or subcontractors licensed therefor by all governmental agencies
having or asserting jurisdiction.
13.03 Tenant, at its expense, and with diligence and dispatch, shall
procure the cancellation or discharge of all notices of violation arising from
or otherwise connected with Tenant's Changes which shall be issued by the
Department of Buildings or any other public or quasi-public authority having or
asserting jurisdiction. Tenant shall defend, indemnify and save harmless
Landlord against any and all mechanic's and other liens filed in connection with
Xxxxxx's Changes, including the liens of any security interest in, conditional
sales of, or chattel mortgages upon, any materials, fixtures or articles so
installed in and constituting part of the Demised Premises and against all
costs, expense and liabilities incurred in connection with any such lien,
security interest, conditional sale or chattel mortgage or any action or
proceeding brought thereon. Tenant, at its expense, shall procure the
satisfaction or discharge of all such liens within thirty (30) days after
Landlord makes written demand therefor. However, nothing herein contained shall
prevent Tenant from contesting, in good faith and at its own expense, any such
notice of violation, provided that Tenant shall comply with the provisions of
Section 10.02.
13.04 Xxxxxx agrees that the exercise of its rights pursuant to the
provisions of this Article 13 shall not be done in a manner which would create
any work stoppage, picketing, labor disruption or dispute or violate Landlord's
union contracts affecting the Land and/or Building nor unreasonable interference
with the business of Landlord or any Tenant or occupant of the Building. In the
event of the occurrence of any condition described above arising from the
exercise by Tenant of its right pursuant to the provisions of this Article 13,
Tenant shall, immediately upon notice from Landlord, cease the manner
-32-
of exercise of such right giving rise to such condition. In the event Tenant
fails to cease such manner of exercise of its rights as aforesaid, Landlord, in
addition to any rights available to it under this lease and pursuant to law,
shall have the right to injunction without notice. With respect to Xxxxxx's
Changes, Tenant shall make all arrangements for, and pay all expenses incurred
in connection with, use of the freight elevators servicing the Demised Premises.
ARTICLE 14
Tenant's Property
14.01 All fixtures, equipment, improvements and appurtenances attached to
or built into the Demised Premises at the commencement of or during the term of
this lease, whether or not by or at the expense of Tenant, shall be and remain a
part of the Demised Premises, shall be deemed the property of Landlord and shall
not be removed by Tenant, except as hereinafter in this Article expressly
provided.
14.02 All panelling, movable partitions, lighting fixtures, special
cabinet work, other business and trade fixtures, machinery and equipment,
communications equipment and office equipment, whether or not attached to or
built into the Demised Premises, which are installed in the Demised Premises by
or for the account of Tenant, without expense to Landlord, and can be removed
without permanent structural damage to the Building, and all furniture,
furnishings and other articles of movable personal property owned by Tenant and
located in the Demised Premises, (all of which are sometimes called "Tenant's
Property") shall be and shall remain the property of Tenant and may be removed
by it at any time during the term of this lease; provided that if any of
Tenant's Property is removed, Tenant or any party or person entitled to remove
same shall repair or pay the cost of repairing any damage to the Demised
Premises or to the Building resulting from such removal. Any equipment or other
property for which Landlord shall have granted any allowance or credit to Tenant
or which has replaced such items originally provided by Landlord at Landlord's
expense shall not be deemed to have been installed by or for the account of
Tenant, without expense to Landlord, and shall not be considered Xxxxxx's
Property.
14.03 At or before the Expiration Date, or the date of any earlier
termination of this lease, or as promptly as practicable after such an earlier
termination date, Tenant at its expense, shall remove from the Demised Premises
all of Tenant's Property except such items thereof a) which constitute initial
installations made by Tenant on the Demised Premises in accordance with Exhibit
C annexed hereto or b) which constitute Tenant changes which were approved by
Landlord or c) such other installations as Tenant shall have expressly agreed in
writing with Landlord were to remain and to become the property of Landlord, and
shall fully repair any damage to the Demised Premises or the Building resulting
from such removal. Tenant's obligation herein shall survive the termination of
the lease.
14.04 Any other items of Tenant's Property (except money, securities and
other like valuables) which shall remain in the Demised Premises after the
Expiration Date or after a period of fifteen (15) days following an earlier
termination date, may, at the option of the Landlord, be deemed to have been
abandoned, and in such case either may be
-33-
retained by Landlord as its property or may be disposed of, without
accountability, at Xxxxxx's expense in such manner as Landlord may see fit.
ARTICLE 15
Repairs And Maintenance
15.01 Tenant shall take good care of the Demised Premises. Tenant, at its
expense, shall promptly, using contractors reasonably acceptable to Landlord,
make all repairs, ordinary or extraordinary, interior or exterior, structural or
otherwise, in and about the Demised Premises and the Building, as shall be
required by reason of (i) the performance or existence of Tenant's Work or
Tenant's Changes, (ii) the installation, use or operation of Tenant's Property
in the Demised Premises, (iii) the moving of Tenant's Property in or out of the
Building, or (iv) the misuse or neglect of Tenant or any of its employees,
agents or contractors; but Tenant shall not be responsible for any of such
repairs as are required by reason of Landlord's neglect or other fault in the
manner of performing any of Tenant's Work or Tenant's Changes which may be
undertaken by Landlord for Tenant's account or are otherwise required by reason
of neglect or other fault of Landlord or its employees, agents or contractors.
Except if required by the neglect or other fault of Landlord or its employees,
agents or contractors, Tenant, at its expense, shall replace all scratched,
damaged or broken doors or other glass (excluding exterior windows) in or about
the Demised Premises and shall be responsible for all repairs, maintenance and
replacement of wall and floor coverings in the Demised Premises and, for the
repair and maintenance of all lighting fixtures therein.
15.02 Landlord, at its expense, shall operate the Building as a
first-class office building and shall keep and maintain the Building and its
fixtures, appurtenances, systems and facilities serving the Demised Premises, in
good working order, condition and repair and shall make all repairs, structural
and otherwise, interior and exterior, as and when needed in or about the Demised
Premises, except for those repairs for which Tenant is responsible pursuant to
any other provisions of this lease.
15.03 Except as expressly otherwise provided in this lease, Landlord shall
have no liability to Tenant by reason of any inconvenience, annoyance,
interruption or injury to business arising from Landlord's making any repairs or
changes which Landlord is required or permitted by this lease, or required by
law, to make in or to any portion of the Building or the Demised Premises, or in
or to the fixtures, equipment or appurtenances of the Building or the Demised
Premises, provided that Landlord shall use due diligence with respect thereto
and shall perform such work, except in case of emergency, at times reasonably
convenient to Tenant and otherwise in such manner as will not materially
interfere with Xxxxxx's use of the Demised Premises.
ARTICLE 16
Electricity
16.01 (a) Landlord agrees that, prior to Commencement Date, risers,
feeders and wiring will be installed in the Building by Landlord so as
adequately to supply Tenant's electrical requirements in accordance with
Tenant's plans for initial occupancy and the provisions in the Work Letter
(Exhibit C) as to the service capacity of electric risers to furnish
electric service to the Demised Premises.
-34-
(b) Tenant shall obtain and pay for Tenant's entire separate supply
of electric current by direct application to and arrangement with the
public utility company servicing the Building. Landlord will permit its
electric feeders, risers and wiring serving the Demised Premises to be
used by Tenant to the extent available and safely capable of being used
for such purpose.
16.02 After the initial installation work by Landlord, any additional
risers, feeders or other equipment or service proper or necessary to supply
Tenant's electrical requirements, upon written request of Tenant, will be
installed by Landlord, at the sole cost and expense of Tenant, if in Landlord's
sole judgment, the same are necessary and will not cause permanent damage or
injury to the Building or the Demised Premises or cause or create a dangerous or
hazardous condition or entail excessive or unreasonable alterations, repairs or
expense or interfere with or disturb other tenants or occupants. Rigid conduit
only will be allowed.
16.03 Landlord shall not in anywise be liable or responsible to Tenant for
any loss or damage or expense which Tenant may sustain or incur if either the
quantity or character of electric service is changed or is no longer available
or suitable for Tenant's requirements except as a result of Xxxxxxxx's
negligence.
16.04 Tenant agrees not to connect any additional electrical equipment of
any type to the Building electric distribution system, beyond that on Tenant's
approved plans for initial occupancy, other than lamps, typewriters and other
small office machines which consume comparable amounts of electricity, without
the Landlord's prior written consent, which consent shall not be unreasonably
withheld or delayed. In no event shall Tenant use or install any fixtures,
equipment or machines the use of which in conjunction with other fixtures,
equipment and machines in the Demised Premises would result in an overload of
the electrical circuits servicing the Demised Premises.
16.05 Tenant covenants and agrees that at all times its use of electric
current shall never exceed the capacity of the then existing feeders to the
Building or the risers or wiring installation. Tenant shall furnish, install and
replace, as required, all lighting tubes, lamps, bulbs and ballasts required in
the Demised Premises, at Tenant's sole cost and expense. All lighting tubes,
lamps, bulbs and ballasts so installed shall become Landlord's property upon the
expiration or sooner termination of this lease.
ARTICLE 17
Heat, Ventilation And Air-Conditioning
17.01 Landlord, at its sole cost and expense, shall furnish and install in
the Demised Premises heating and air-conditioning units which shall be connected
to the Building's heating and air-conditioning systems and water tower in
accordance with the specifications for the system installed.
17.02 Use of the Demised Premises, or any part thereof, in a manner
exceeding the design conditions (including occupancy and connected electrical
load) specified in Exhibit C for the heating or cooling units in the Demised
Premises, or rearrangement of partitioning which interferes with normal
operation of the heat, ventilation and air-
-35-
conditioning in the Demised Premises, may require changes in the heat,
ventilation and air-conditioning system servicing the Demised Premises. Such
changes, so occasioned, shall be made by Tenant, at its expense, as Xxxxxx's
Changes pursuant to Article 13.
17.03 Landlord, at its expense, shall maintain and operate the heating,
ventilating and air-conditioning systems (hereafter called the "systems") and,
subject to energy conservation requirements of governmental authorities, shall
furnish heat, ventilating and air-conditioning (hereinafter collectively called
"air-conditioning service") in the Demised Premises through the systems, which
shall be in compliance with the performance specifications in the Work Letter
attached hereto as Exhibit C, as may be reasonably required for comfortable
occupancy of the Demised Premises during "regular hours" (that is between the
hours of 7:00 A.M. and 7:00 P.M. weekdays and 8:00 A.M. and 1:00 P.M. on
Saturdays) or "business days" (as defined in Section 44.03) throughout the year.
If Tenant shall require heating, ventilating or air-conditioning service at any
other time (hereinafter called "after hours"), Landlord shall furnish such after
hours service upon reasonable advance notice from Tenant, and Tenant shall pay
on demand Landlord's actual cost of furnishing such service including the cost
of labor and utilities and depreciation of equipment plus 10%; such costs to
exclude overhead and administrative charges. In the event the after hours
service is shared by other tenants, the cost thereof shall be prorated among all
such tenants.
ARTICLE 18
Landlord's Other Services, Security
18.01 Landlord, at its expense, shall provide public elevator service,
passenger and freight, by elevators serving the floor on which the Demised
Premises are situated during regular hours of business days, and shall have at
least one passenger elevator subject to call at all other times.
18.02 Tenant, at its expense, shall cause the Demised Premises to be
cleaned and maintained as first class office space. Landlord agrees to cause the
common areas of the Building to be cleaned in a manner consistent with the
operation of a first-class office building.
18.03 Landlord, at its expense, shall furnish adequate hot and cold water
to the Demised Premises for drinking, lavatory and cleaning purposes. If Tenant
uses water for any other purpose Landlord, at Tenant's expense, shall install
meters to measure Tenant's consumption of cold water and/or hot water for such
other purposes and/or steam, as the case may be. Tenant shall pay for the
quantities of cold water and hot water shown on such meters, at Landlord's cost
thereof, on the rendition of Landlord's bills therefor.
18.04 Landlord, at its expense, and on Tenant's request, shall maintain
the original listings on the Building directory of the names of Xxxxxx, and the
names of any of their officers and employees, provided that the names so listed
shall not take up more than Xxxxxx's Proportionate Share of the spaces on the
Building directory. In the event Tenant shall require additional or substitute
listings on the Building directory, Landlord shall, to the extent space for such
additional or substitute listing is available, maintain such listings and Tenant
shall pay to Landlord an amount equal to Landlord's actual cost therefor with no
mark up.
-36-
18.05 Landlord reserves the right, without any liability to Tenant, except
as otherwise expressly provided in this lease, to stop service of any of the
heating, ventilating, air conditioning, electric, sanitary, elevator or other
Building systems serving the Demised Premises, or the rendition of any of the
other services required of Landlord under this lease, whenever and for so long
as may be necessary, by reason of accidents, emergencies, strikes or the making
of repairs or changes which Landlord is required by this lease or by law to make
or in good xxxxx xxxxx necessary, by reason of difficulty in securing proper
supplies of fuel, steam, water, electricity, labor or supplies, or by reason of
any other cause beyond Landlord's reasonable control.
18.06 Landlord agrees that throughout the term of this lease it will
install and operate a security system consistent with the operation of a
first-class office building. In the event that Tenant desires to install a
separate security system for its own premises, Landlord agrees that Tenant shall
have the right, at Tenant's own cost and expense, to install a guard station in
the lobby in the vicinity of Tenant's exclusive elevators, the exact location to
be agreed upon between Landlord and Tenant. The cost of Tenant's security staff
and any security device installed by Tenant shall be borne solely by Xxxxxx.
ARTICLE 19
Access, Changes In Building Facilities, Name
19.01 All of the Building except the inside surfaces of all walls, windows
and doors bounding the Demised Premises (including exterior Building walls, core
corridor walls and doors and any core corridor entrance) and any space in or
adjacent to the Demised Premises used for shafts, stacks, pipes, conduits, fan
rooms, ducts, electric or other utilities, sinks or other Building facilities,
and the use thereof, as well as access thereto through the Demised Premises for
the purpose of operation, maintenance, decoration and repair, are reserved to
Landlord.
19.02 Tenant shall permit Landlord to install, use, replace and maintain
pipes, ducts and conduits within the demising walls, bearing columns and
ceilings of the Demised Premises.
19.03 Landlord or Xxxxxxxx's agent shall have the right, upon request
(except in emergency under clause (ii) hereof) to enter and/or pass through the
Demised Premises or any part thereof, at reasonable times during reasonable
hours, (i) to examine the Demised Premises and to show them to the fee owners,
lessors of superior leases, holders of superior mortgages, or prospective
purchasers, mortgagees or lessees of the Building as an entirety, and (ii) for
the purpose of making such repairs or changes in or to the Demised Premises or
in or its facilities, as may be provided for by this lease or as may be mutually
agreed upon by the parties or as Landlord may be required to make by law or in
order to repair and maintain said structure or its fixtures or facilities.
Landlord shall be allowed to take all materials into and upon the Demised
Premises that may be required for such repairs, changes, repainting or
maintenance, without liability to Tenant, but Landlord shall not unreasonably
interfere with Xxxxxx's use of the Demised Premises. Landlord shall also have
the right to enter on and/or pass through the Demised Premises, or any part
thereof, at such times as such entry shall be required by circumstances of
emergency affecting the Demised Premises or said structure.
-37-
19.04 During the period of twelve (12) months prior to the Expiration Date
Landlord may exhibit the Demised Premises to prospective tenants.
19.05 Landlord reserves the right, at any time after completion of the
Building, without incurring any liability to Tenant therefor, to make such
changes in or to the Building and the fixtures and equipment thereof, as well as
in or to the street entrances, halls, passages, elevators, escalators and
stairways thereof, as it may deem necessary or desirable, provided that any such
changes (i) do not unreasonably interfere with Xxxxxx's access to the Demised
Premises, (ii) do not unreasonably interfere with the use of the Demised
Premises, (iii) do not materially reduce the area of the Demised Premises, and
(iv) do not permanently and materially reduce the services furnished to the
Demised Premises.
19.06 Landlord may adopt any name for the Building. Landlord reserves the
right to change the name or address of the Building at any time, subject to the
provisions of Article 43.
19.07 For the purposes of Article 19, the term "Landlord" shall include
lessors of leases and the holders of mortgages to which this lease is subject
and subordinate as provided in Article 7.
19.08 Landlord agrees that except in the event of an emergency, any access
to the Demised Premises shall be subject to reasonable notice to the Tenant,
shall be on an escorted basis and that Xxxxxxxx's right of access shall be
performed in a manner not to unreasonably interfere with Xxxxxx's use of the
Demised Premises.
ARTICLE 20
Notice Of Accidents
20.01 Tenant shall give notice to Landlord, promptly after Xxxxxx learns
thereof, of (i) any accident in or about the Demised Premises for which Landlord
might be liable, (ii) all fires in the Demised Premises, (iii) all damages to or
defects in the Demised Premises, including the fixtures, equipment and
appurtenances thereof, for the repair of which Landlord might be responsible,
and (iv) all damage to or defects in any parts or appurtenances of the
Building's sanitary, electrical, heating, ventilating, air-conditioning,
elevator and other systems located in or passing through the Demised Premises or
any part thereof.
ARTICLE 21
Non-Liability And Indemnification
21.01 Neither Landlord nor any agent or employee of Landlord shall be
liable to Tenant for any injury or damage to Tenant or to any other person or
for any damage to, or loss (by theft or otherwise) of, any property of Tenant or
of any other person, irrespective of the cause of such injury, damage or loss,
unless caused by the wrongful act or due to the negligence of Landlord, its
agents or employees occurring within the scope of their respective employments
without negligence on the part of Tenant, it being understood
-38-
that no property, other than such as might normally be brought upon or kept in
the Demised Premises as an incident to the reasonable use of the Demised
Premises for the purpose herein permitted, will be brought upon or be kept in
the Demised Premises.
21.02 Tenant shall indemnify and save harmless Landlord and its agents
against and from (a) any and all claims (i) arising from (x) the conduct or
management of the Demised Premises or of any business therein, or (y) any work
or thing whatsoever done, or any condition created (other than by Landlord for
Landlord's or Tenant's account) in or about the Demised Premises during the term
of this lease or during the period of time, if any, prior to the Commencement
Date that Tenant may have been given access to the Demised Premises, or (ii)
arising from any negligent or otherwise wrongful act or omission of Tenant or
any of its subtenants or licensees or its or their employees, agents or
contractors, and (b) all costs, expenses and liabilities incurred in or in
connection with each such claim or action or proceeding brought thereon. In case
any action or proceeding be brought against Landlord by reason of any such
claim, Tenant, upon notice from Landlord, shall resist and defend such action or
proceeding. Notwithstanding the foregoing, nothing herein contained shall
require Tenant to indemnify Landlord against any claims based upon any accident,
injury or damage on or about the Demised Premises, arising out of the negligence
or willful act of Landlord or any agent of Landlord.
21.03 Except as provided in Section 3.01 and as otherwise expressly
provided in this lease, this lease and the obligations of Tenant hereunder shall
be in no wise affected, impaired or excused because Landlord is unable to
fulfill, or is delayed in fulfilling, any of its obligations under this lease by
reason of strike, other labor trouble, governmental preemption or priorities or
other controls in connection with a national or other public emergency or
shortages of fuel, supplies or labor resulting therefrom, acts of God or other
like cause beyond Landlord's reasonable control.
ARTICLE 22
Destruction Or Damage
22.01 If the Building or the Demised Premises shall be partially or
totally damaged or destroyed by fire or other cause, then, whether or not the
damage or destruction shall have resulted from the fault or neglect of Tenant,
or its employees, agents or visitors (and if this lease shall not have been
terminated as in this Article hereinafter provided), Landlord shall, to the
extent of insurance proceeds received by it, repair the damage and restore and
rebuild the Building and/or the Demised Premises to a condition equivalent (with
respect to character, quality, value, utility and appearance and the Building
systems) to that which existed immediately prior to such damage with reasonable
dispatch after notice to it of the damage or destruction; provided, however,
that Landlord shall not be required to repair or replace any of Tenant's
Property nor to restore any Tenant's Work.
22.02 (a) If the Building or the Demised Premises shall be partially
damaged or partially destroyed by fire or other cause, the rents payable
hereunder shall be abated to the extent that the Demised Premises shall have
been rendered untenantable and for the period from the date of such damage or
destruction to the date the damage shall be repaired or restored. If the Demised
Premises or a major part thereof shall be totally (which shall be deemed to
include substantially totally) damaged or destroyed or rendered
-39-
completely (which shall be deemed to include substantially completely)
untenantable on account of fire or other cause, the rents shall xxxxx as of the
date of the damage or destruction and until Landlord shall repair, restore and
rebuild the Building and the Demised Premises, provided, however, that should
Tenant reoccupy a portion of the Demised Premises during the period the
restoration work is taking place and prior to the date that the same are made
completely tenantable, rents allocable to such portion shall be payable by
Tenant from the date of such occupancy.
(b) Notwithstanding anything to the contrary contained herein, prior
to the date the Demised Premises, or any affected portion thereof, are made
completely tenantable, Landlord shall provide Tenant and Tenant's contractor,
subcontractors and materialmen access to the Demised Premises to perform any
alterations required to prepare the Demised Premises for the conduct of Xxxxxx's
business (hereinafter referred to as "Specialty Alterations") on the following
terms and conditions:
(i) Tenant shall not commence work in any portion of the Demised
Premises until the date specified in a notice from Landlord to Tenant stating
that the repairs required to be made by Landlord have been or will be completed
to the extent reasonably necessary, in Landlord's reasonable discretion, to
permit the commencement of the Specialty Alterations to be performed in the
portion in question without interference with, and consistent with the
performance of, the repairs remaining to be performed; and
(ii) Such access by Tenant shall be deemed to be subject to all of
the applicable provisions of this lease, except that there shall be no
obligation on the part of Tenant solely because of such access to pay any fixed
rent or additional rent with respect to the affected portion of the Demised
Premises for any period prior to the date the damage thereto shall be repaired
or restored in accordance with the provisions hereof.
22.03 If the Building or the Demised Premises shall be totally damaged or
destroyed by fire or other cause, or if the Building shall be so damaged or
destroyed by fire or other cause (whether or not the Demised Premises are
damaged or destroyed) that its repair or restoration requires the expenditure,
as estimated by a reputable contractor or architect designated by Landlord and
approved by Tenant, which approval shall not be unreasonably withheld or
delayed, of more than 40% of the full insurable value of the Building
immediately prior to the casualty, then in either such case Landlord may
terminate this lease by giving Tenant notice to such effect within one hundred
twenty (120) days after the date of the casualty; provided that if the Demised
Premises are not substantially damaged or rendered substantially untenantable,
Landlord may not terminate this lease unless it shall elect to terminate leases
(including this lease), affecting at least fifty percent (50%) of the rentable
area of the Building (excluding any rentable area occupied by Landlord or its
affiliates).
22.04(a) Anything contained in this Article 22 to the contrary
notwithstanding, within thirty (30) days after notice to Landlord of any damage
described in Section 22.01 hereof, Landlord shall deliver to Tenant a statement
prepared by a reputable contractor approved by Tenant, which approval shall not
be unreasonably withheld or delayed, setting forth such contractor's estimate as
to the time and monies required to repair such damage and the assumptions
regarding the use of labor (including overtime labor, if applicable) and
construction methods considered in arriving at such estimate. If the estimated
time period exceeds twelve (12) months from the date of such
-40-
damage or the estimated monies exceeds the anticipated amount of insurance
proceeds (provided Landlord does not agree to supply any deficiency), Tenant may
elect to terminate this lease by notice to Landlord not later than sixty (60)
days following receipt of such statement or, if no statement is delivered, not
earlier than ninety (90) days after the date such statement was to have been
delivered. If Xxxxxx makes such election, the Term shall expire upon a date
specified by Xxxxxx, not exceeding ninety (90) days after notice of such
election is given by Xxxxxx, and Tenant shall vacate the Demised Premises and
surrender the same to Landlord in accordance with the provisions of Article 24
hereof. If Tenant shall not have elected to terminate this lease pursuant to
this Article 22 (or is not entitled to terminate this lease pursuant to this
Article 22), and such repairs are (i) not commenced by Landlord within ninety
(90) days after the date of such damage, (ii) not substantially completed by
Landlord within twelve (12) months after the date of such damage, subject to
unavoidable delays (not exceeding six months) on account of delays in the
adjustment of insurance, labor troubles, governmental controls, act of God, or
any other cause beyond Landlord's reasonable control, Tenant may elect to
terminate this lease by notice to Landlord. If Xxxxxx makes such election, the
Term of this lease shall expire upon the ninetieth (90th) day after notice of
such election is given by Xxxxxx and Tenant shall vacate the Demised Premises
and surrender the same to Landlord in accordance with the provisions of Article
24 hereof.
(b) Notwithstanding the foregoing, if (i) the Demised Premises shall
be substantially damaged during the last two years of the Term (as the same may
be renewed or extended pursuant to Article 40 hereof) or (ii) an engineer
selected by Landlord and approved by Tenant, which approval shall not be
unreasonably withheld or delayed, shall reasonably estimate that there will be
less than two (2) years remaining in the Term (as same may be renewed or
extended pursuant to Article 40 hereof) upon completion of restoration of the
Building or the Demised Premises, as the case may be, then in either such case,
Landlord or Tenant may elect by notice, given within thirty (30) days after the
occurrence of such damage, to terminate this lease. Notwithstanding anything
contained in this lease to the contrary, if there shall occur a casualty at such
time as there shall be estimated to be less than two years remaining in the Term
of this lease after completion of restoration but prior to the time that
pursuant to the provisions of Article 40 hereof Tenant shall have the right to
exercise any renewal option granted hereunder, then, prior to Landlord
terminating this lease, Tenant shall have the right to exercise any renewal
option granted herein in accordance with the provisions of Article 40 hereof. If
either party shall elect to so terminate this lease, the Term shall expire upon
the ninetieth (90th) day after notice of such election is given by such party
and Tenant shall vacate the Demised Premises and surrender the same to Landlord
in accordance with the provisions of Article 24 hereof.
22.05 No damages, compensation or claim shall be payable by Landlord for
inconvenience, loss of business or annoyance arising from any repair or
restoration of any portion of the Demised Premises or of the Building pursuant
to this Article. Landlord shall use its best efforts to effect such repair or
restoration promptly and in such manner as to not unreasonably interfere with
Xxxxxx's use and occupancy.
22.06 Xxxxxx agrees to cooperate with Landlord to enable Landlord to
promptly collect any insurance proceeds to which it may be entitled.
Notwithstanding any of the foregoing provisions of this Article, if Landlord or
the lessor of any superior lease or the holder of any superior mortgage shall be
unable to collect all of the insurance proceeds
-41-
(including rent insurance proceeds) applicable to damage or destruction of the
Demised Premises or the Building by fire or other cause, by reason of some
action or inaction on the part of Tenant or any of its employees, agents or
contractors which constitutes a breach of the provisions of this lease, then,
without prejudice to any other remedies which may be available against Tenant,
there shall be no abatement of Tenant's rents, but the total amount of such
rents not abated (which would otherwise have been abated) shall not exceed the
amount of the uncollected insurance proceeds.
22.07 Landlord will not carry insurance of any kind on Tenant's Property
or Tenant's Work, and, except as provided by law or by reason of its fault or
its breach of any of its obligations hereunder, shall not be obligated to repair
any damage thereto or replace the same.
22.08 The provisions of this Article shall be considered an express
agreement governing any case of damage or destruction of the Demised Premises by
fire or other casualty and any applicable law providing for a contingency in the
absence of an express agreement now or hereafter in force shall have no
application in such case.
22.09 Any dispute which may arise between the parties with respect to the
meaning or application of any of the provisions of this Article 22 shall be
determined by arbitration in the manner provided in Article 34 hereof.
ARTICLE 23
Eminent Domain
23.01 If the whole of the Building shall be lawfully taken by condemnation
or in any other manner for any public or quasi-public use or purpose, this lease
and the term and estate hereby granted shall forthwith terminate as of the date
of vesting of title in such taking (which date is hereinafter also referred to
as the "date of the taking"), and the rents shall be prorated and adjusted as of
such date.
23.02 If only a part of the Building shall be so taken, this lease shall
be unaffected by such taking, except that Tenant may elect to terminate this
lease in the event of a partial taking, if the remaining area of the Demised
Premises shall not be reasonably sufficient for Tenant to continue feasible
operation of its business. Tenant shall give notice of such election to Landlord
not later than thirty (30) days after (i) notice of such taking is given by
Landlord to Tenant, or (ii) the date of such taking, whichever occurs sooner.
Upon the giving of such notice by Tenant this lease shall terminate on the date
of such taking and the rents shall be prorated as of such termination date. Upon
such partial taking and this lease continuing in force as to any part of the
Demised Premises, the rents apportioned to the part taken shall be prorated and
adjusted as of the date of taking and from such date the fixed rent for the
Demised Premises and additional rent shall be payable pursuant to Article 5
according to the rentable area remaining.
23.03 Landlord shall be entitled to receive the entire award in any
proceeding with respect to any taking provided for in this Article without
deduction therefrom for any estate vested in Tenant by this lease and Tenant
shall receive no part of such award, except as hereinafter expressly provided in
this Article. Tenant hereby expressly assigns to Landlord all of its right,
title and interest in or to every such award. Notwithstanding
-42-
anything herein to the contrary, Tenant may, at its sole cost and expense, make
a claim with the condemning authority for Xxxxxx's moving expenses, the value of
Tenant's Property or fixtures or Tenant's Changes which do not become part of
the Building or property of the Landlord, provided however that Landlord's award
is not thereby reduced or otherwise adversely affected.
23.04 If the temporary use or occupancy of all or any part of the Demised
Premises shall be lawfully taken by condemnation or in any other manner for any
public or quasi-public use or purpose during the term of this lease, Tenant
shall be entitled, except as hereinafter set forth, to receive that portion of
the award for such taking which represents compensation for the use and
occupancy of the Demised Premises and, if so awarded, for the taking of Tenant's
Property and for moving expenses, and Landlord shall be entitled to receive that
portion which represents reimbursement for the cost of restoration of the
Demised Premises. This lease shall be and remain unaffected by such taking and
Tenant shall continue responsible for all of its obligations hereunder insofar
as such obligations are not affected by such taking and shall continue to pay in
full the fixed rent and additional rent when due. If the period of temporary use
or occupancy shall extend beyond the Expiration Date, that part of the award
which represents compensation for the use or occupancy of the Demised Premises
(or a part thereof) shall be divided between Landlord and Tenant so that Tenant
shall receive so much thereof as represents the period prior to the Expiration
Date and Landlord shall receive so much thereof as represents the period
subsequent to the Expiration Date. All moneys received by Xxxxxx as, or as part
of, an award for temporary use and occupancy for a period beyond the date to
which the rents hereunder have been paid by Tenant shall be received, held and
applied by Xxxxxx as a trust fund for payment of the rents falling due
hereunder.
23.05 In the event of any taking of less than the whole of the Building
which does net result in a termination of this lease, or in the event of a
taking for a temporary use or occupancy of all or any part of the Demised
Premises which does not extend beyond the Expiration Date, Landlord, at its
expense, and to the extent any award or awards shall be sufficient for the
purpose, shall proceed with reasonable diligence to repair, alter and restore
the remaining parts of the Building and the Demised Premises to substantially
the same or equal condition that existed prior to the taking to the extent that
the same may be feasible and so as to constitute a complete and tenantable
Building and Demised Premises.
23.06 Should any part of the Demised Premises be taken to effect
compliance with any law or requirement of public authority other than in the
manner hereinabove provided in this Article, then (i) if such compliance is the
obligation of Tenant under this lease, Tenant shall not be entitled to any
diminution or abatement of rent or other compensation from Landlord therefor,
but (ii) if such compliance is the obligation of Landlord under this lease, the
fixed rent hereunder shall be reduced and additional rents under Article 5 shall
be adjusted in the same manner as is provided in Section 23.02 according to the
reduction in rentable area of the Demised Premises resulting from such taking.
23.07 Any dispute which may arise between the parties with respect to the
meaning or application of any of the provisions of this Article shall be
determined by arbitration in the manner provided in Article 34.
-43-
ARTICLE 24
Surrender
24.01 On the last day of the term of this lease, or upon any earlier
termination of this lease, or upon any re-entry by Landlord upon the Demised
Premises, Tenant shall quit and surrender the Demised Premises to Landlord in
good order, condition and repair, except for ordinary wear and tear and
condemnation, damage and destruction by fire or other casualty and Tenant shall
remove all of Tenant's Property therefrom except as otherwise expressly provided
in this lease and shall restore the Demised Premises wherever such removal
results in damage thereto.
ARTICLE 25
Conditions Of Limitation
25.01 To the extent permitted by applicable law this lease and the term
and estate hereby granted are subject to the limitation that whenever Tenant
shall make an assignment of the property of Tenant for the benefit of creditors,
or shall file a voluntary petition under any bankruptcy or insolvency law, or an
involuntary petition alleging an act of bankruptcy or insolvency shall be filed
against Tenant under any bankruptcy or insolvency law, or whenever a petition
shall be filed by or against Tenant under the reorganization provisions of the
United States Bankruptcy Act or under the provisions of any law of like import,
or whenever a petition shall be filed by Tenant under the arrangement provisions
of the United States Bankruptcy Act or under the provisions of any law of like
import, or whenever a permanent receiver of Tenant or of or for the property of
Tenant shall be appointed, then, Landlord, (a) at any time after receipt of
notice of the occurrence of any such event, or (b) if such event occurs without
the acquiescence of Tenant, at any time after the event continues for one
hundred twenty (120) days, Landlord may give Tenant a notice of intention to end
the term of this lease at the expiration of five (5) days from the date of
service of such notice of intention, and upon the expiration of said five (5)
day period this lease and the term and estate hereby granted, whether or not the
term shall theretofore have commenced, shall terminate with the same effect as
if that day were the Expiration Date, but Tenant shall remain liable for damages
as provided in Article 27.
25.02 This lease and the term and estate hereby granted are subject to the
further limitation that:
(a) whenever Tenant shall default in the payment of any installment
of fixed rent, or in the payment of any additional rent or any other charge
payable by Tenant to Landlord, on any day upon which the same ought to be paid,
and such default shall continue for ten (10) days after Landlord shall have
given Tenant a notice specifying such default, or
(b) whenever Tenant shall do or permit anything to be done, whether
by action or inaction, contrary to any of Tenant's obligations hereunder, and if
such situation shall continue and shall not be remedied by Tenant within thirty
(30) days after Landlord shall have given to Tenant a notice specifying the
same, or, in the case of a happening or default which cannot with due diligence
be cured within a period of thirty (30) days and
-44-
the continuance of which for the period required for cure will not subject
Landlord to the risk of criminal liability (as more particularly described in
Section 10.02) or termination of any superior lease or foreclosure of any
superior mortgage, if Tenant shall not, (i) within said thirty (30) day period
advise Landlord of Tenant's intention to duly institute all steps necessary to
remedy such situation, (ii) duly institute within said thirty (30) day period,
and thereafter diligently prosecute to completion all steps necessary to remedy
the same and (iii) complete such remedy within such time after the date of the
giving of said notice of Landlord as shall reasonably be necessary, or
(c) whenever any event shall occur or any contingency shall arise
whereby this lease or the estate hereby granted or the unexpired balance of the
term hereof would, by operation of law or otherwise, devolve upon or pass to any
person, firm or corporation other than Tenant, except as expressly permitted by
Article 9, or
then in any of said cases set forth in the foregoing Subsections (a), (b) and
(c) Landlord may give to Tenant a notice of intention to end the term of this
lease at the expiration of five (5) days from the date of the service of such
notice of intention, and upon the expiration of said five (5) days this lease
and the term and estate hereby granted, whether or not the term shall
theretofore have commenced, shall terminate with the same effect as if that day
were the Expiration Date, but Tenant shall remain liable for damages as provided
in Article 27.
ARTICLE 26
Re-Entry By Landlord
26.01 If this lease shall expire as in Article 25 provided, Landlord or
Landlord's agents and employees may immediately or at any time thereafter
re-enter the Demised Premises, or any part thereof, in the name of the whole,
either by summary dispossess proceedings or by any suitable action or proceeding
at law, or by force or otherwise, without being liable to indictment,
prosecution or damages therefor, and may repossess the same, and may remove any
persons therefrom, to the end that Landlord may have, hold and enjoy the Demised
Premises again as and of its first estate and interest therein. The word
re-enter, as herein used, is not restricted to its technical legal meaning. In
the event of any termination of this lease under the provisions of Article 25 or
if Landlord shall re-enter the Demised Premises under the provisions of this
Article or in the event of the termination of this lease, or of re-entry, by or
under any summary dispossess or other proceeding or action or any provision of
law by reason of default hereunder on the part of Tenant, Tenant shall thereupon
pay to Landlord the fixed rent and additional rent payable by Tenant to Landlord
up to the time of such termination of this lease, or of such recovery of
possession of the Demised Premises by Landlord, as the case may be, and shall
also pay to Landlord damages as provided in Article 27.
26.02 In the event of a breach or threatened breach by Tenant of any of
its obligations under this lease, Landlord shall also have the right of
injunction. The special remedies to which Landlord may resort hereunder are
cumulative and are not intended to be exclusive of any other remedies or means
of redress to which Landlord may lawfully be entitled at any time and Landlord
may invoke any remedy allowed at law or in equity as if specific remedies were
not provided for herein.
-45-
26.03 If this lease shall terminate under the provisions of Article 25, or
if Landlord shall re-enter the Demised Premises under the provisions of this
Article, or in the event of the termination of this lease, or of re-entry, by or
under any summary dispossess or other proceeding or action or any provision of
law by reason of default hereunder on the part of Tenant, Landlord shall be
entitled to retain all moneys, if any, paid by Tenant to Landlord, whether as
advance rent, security or otherwise, but such moneys shall be credited by
Landlord against any fixed rent or additional rent due from Tenant at the time
of such termination or re-entry or, at Landlord's option, against any damages
payable by Xxxxxx under Article 27 or pursuant to law.
ARTICLE 27
Damages
27.01 If this lease is terminated under the provisions of Article 25, or
if Landlord shall re-enter the Demised Premises under the provisions of Article
26, or in the event of the termination of this lease, or of re-entry, by or
under any summary dispossess or other proceeding or action or any provision of
law by reason of default hereunder on the part of Tenant, Tenant shall pay to
Landlord as damages, at the election of Landlord, either:
(a) a sum which at the time of such termination of this lease or at
the time of any such re-entry by Landlord, as the case may be, represents the
then value of the excess, if any, of
(1) the aggregate of the fixed rent and the additional rent
payable hereunder which would have been payable by
Xxxxxx (conclusively presuming the additional rent to be
the same as was payable for the year immediately
preceding such termination) for the period commencing
with such earlier termination of this lease or the date
of any such re-entry, as the case may be, and ending
with the Expiration Date, had this lease not so
terminated or had Landlord not so re-entered the Demised
Premises, over
(2) the aggregate fair rental value of the Demised Premises
for the same period, or
(b) sums equal to the fixed rent and the additional rent (as above
presumed) payable hereunder which would have been payable by Xxxxxx had this
lease not so terminated, or had Landlord not so re-entered the Demised Premises,
payable upon the due dates therefor specified herein following such termination
or such re-entry and until the Expiration Date, provided, however, that if
Landlord shall relet the Demised Premises during said period, Landlord shall
credit Tenant with the net rents received by Landlord from such reletting, such
net rents to be determined by first deducting from the gross rents as and when
received by Landlord from such reletting the expenses incurred or paid by
Landlord in terminating this lease or in re-entering the Demised Premises and in
securing possession thereof, as well as the expenses of reletting, including
altering and preparing the Demised Premises for new tenants, brokers'
commissions, and all other expenses properly chargeable against the Demised
Premises and the rental therefrom; it being understood that any such reletting
may be for a period shorter or longer than the
-46-
remaining term of this lease; but in no event shall Tenant be entitled to
receive any excess of such net rents over the sums payable by Tenant to Landlord
hereunder, nor shall Tenant be entitled in any suit for the collection of
damages pursuant to this Subsection to a credit in respect of any net rents from
a reletting, except to the extent that such net rents are actually received by
Landlord. If the Demised Premises or any part thereof should be relet in
combination with other space, then proper apportionment on a square foot basis
(for equivalent space) shall be made of the rent received from such reletting
and of the expenses of reletting.
If the Demised Premises or any part thereof be relet by Landlord for the
unexpired portion of the term of this lease, or any part thereof, before
presentation of proof of such damages to any court, commission or tribunal, the
amount of rent reserved upon such reletting shall, prima facie, be the fair and
reasonable rental value for the Demised Premises, or part thereof, so relet
during the term of the reletting.
27.02 Suit or suits for the recovery of such damages, or any installments
thereof, may be brought by Landlord from time to time at its election, and
nothing contained herein shall be deemed to require Landlord to postpone suit
until the date when the term of this lease would have expired if it had not been
so terminated under the provisions of Article 25, or under any provision of law,
or had Landlord not re-entered the Demised Premises. Nothing herein contained
shall be construed to limit or preclude recovery by Landlord against Tenant of
any sums or damages to which, in addition to the damages particularly provided
above, Landlord may lawfully be entitled by reason of any default hereunder on
the part of Tenant. Nothing herein contained shall be construed to limit or
prejudice the right of Landlord to prove for and obtain as liquidated damages by
reason of the termination of this lease or re-entry on the Demised Premises for
the default of Tenant under this lease, an amount equal to the maximum allowed
by any statute or rule of law in effect at the time when, and governing the
proceedings in which, such damages are to be proved whether or not such amount
be greater, equal to, or less than any of the sums referred to in Section 27.01.
ARTICLE 28
Waivers
28.01 Tenant, for Tenant, and on behalf of any and all persons claiming
through or under Tenant, including creditors of all kinds, does hereby waive and
surrender all right and privilege which they or any of them might have under or
by reason of any present or future law, to redeem the Demised Premises or to
have a continuance of this lease for the term hereby demised after being
dispossessed or ejected therefrom by process of law or under the terms of this
lease or after the termination of this lease as herein provided.
28.02 In the event that Tenant is in arrears in payment of fixed rent or
additional rent hereunder, Tenant waives Tenant's right, if any, to designate
the items against which any payments made by Tenant are to be credited, and
Xxxxxx agrees that Landlord may apply any payments made by Tenant to any items
it sees fit, irrespective of and notwithstanding any designation or request by
Xxxxxx as to the items against which any such payments shall be credited.
-47-
28.03 Landlord and Tenant hereby waive trial by jury in any action,
proceeding or counterclaim brought by either against the other on any matter
whatsoever arising out of or in any way connected with this lease, the
relationship of Landlord and Tenant, Xxxxxx's use or occupancy of the Demised
Premises, including any claim of injury or damage, or any emergency or other
statutory remedy with respect thereto.
28.04 The provisions of Articles 17 and 18 shall be considered expressed
agreements governing the services to be furnished by Landlord, and Tenant agrees
that any laws and/or requirements of public authorities, now or hereafter in
force, shall have no application in connection with any enlargement of
Landlord's obligations with respect to such services unless Xxxxxx agrees, in
writing, to pay to Landlord, as additional rent, Landlord's reasonable charges
for any additional services provided.
ARTICLE 29
No Other Waivers Or Modifications
29.01 The failure of either party to insist in any one or more instances
upon the strict performance of any one or more of the obligations of this lease,
or to exercise any election herein contained, shall not be construed as a waiver
or relinquishment for the future of the performance of such one or more
obligations of this lease or of the right to exercise such election, but the
same shall continue and remain in full force and effect with respect to any
subsequent breach, act or omission. No executory agreement hereafter made
between Landlord and Tenant shall be effective to change, modify, waive,
release, discharge, terminate or effect an abandonment of this lease, in whole
or in part, unless such executory agreement is in writing, refers expressly to
this lease and is signed by the party against whom enforcement of the change,
modification, waiver, release, discharge or termination or effectuation of the
abandonment is sought.
29.02 The following specific provisions of this Section shall not be
deemed to limit the generality of any of the foregoing provisions of this
Article:
(a) No agreement to accept a surrender of all or any part of the
Demised Premises shall be valid unless in writing and signed by Landlord. The
delivery of keys to an employee of Landlord or of its agent shall not operate as
a termination of this lease or a surrender of the Demised Premises. If Tenant
shall at any time request Landlord to sublet the Demised Premises for Tenant's
account, Landlord or its agent is authorized to receive said keys for such
purposes without releasing Tenant from any of its obligations under this lease,
and Tenant hereby releases Landlord from any liability for loss or damage to any
of Tenant's property in connection with such subletting.
(b) The receipt by Landlord of rent with knowledge of breach of any
obligation of this lease shall not be deemed a waiver of such breach.
(c) No payment by Tenant or receipt by Landlord of a lesser amount
than the correct fixed rent or additional rent due hereunder shall be deemed to
be other than a payment on account, nor shall any endorsement or statement on
any check or any letter accompanying any check or payment be deemed an accord
and satisfaction, and Landlord may accept such check or payment without
prejudice to Landlord's right to recover the balance or pursue any other remedy
in this lease or at law provided.
-48-
ARTICLE 30
Curing Tenant's Defaults, Additional Rent
30.01 (a) If Tenant shall default in the performance of any of Tenant's
obligations under this lease, Landlord, without thereby waiving such default,
may (but shall not be obligated to) perform the same for the account and at the
expense of Tenant, without notice, in a case of emergency, and in any other
case, only if such default continues after the expiration of (i) five (5) days
from the date Landlord gives Tenant notice of intention so to do, or (ii) the
applicable grace period provided in Section 25.02 or elsewhere in this lease for
cure of such default, whichever occurs later.
(b) If Tenant is late in making any payment due to Landlord from
Landlord under this lease for five (5) or more days, then interest shall become
due and owing to Landlord on such payment from the date when it was due computed
at the following rates:
(i) for an individual or partnership tenant, computed at the
lesser of (A) the rate specified in Section 30.01(b)(ii)
or (B) the maximum legal rate of interest permitted to
be charged to an individual or partnership in the State
of New Jersey;
(ii) for a corporate tenant, computed at the greater of (A)
one and 25/100 (1.25%) percent per month or (B) two (2%)
percent per annum over the then prime rate of Chase
Manhattan Bank, N.A. but in no event in excess of the
maximum legal rate of interest chargeable to
corporations in the State of New Jersey.
30.02 Bills for any expenses incurred by Landlord in connection with any
such performance by it for the account of Tenant, and bills for all costs,
expenses and disbursements of every kind and nature whatsoever, including
reasonable counsel fees, involved in collecting or endeavoring to collect the
fixed rent or additional rent or any part thereof or enforcing or endeavoring to
enforce any rights against Tenant, under or in connection with this lease, or
pursuant to law, including any such cost, expense and disbursement involved in
instituting and prosecuting summary proceedings, as well as bills for any
property, material, labor or services provided, furnished, or rendered, by
Landlord or at its instance to Tenant, may be sent by Landlord to Tenant
monthly, or immediately, at Landlord's option, and, shall be due and payable in
accordance with the terms of such bills.
ARTICLE 31
Broker
31.01 Landlord and Tenant covenant, warrant and represent to each other
that there was no broker or finder instrumental in consummating this lease. Both
parties acknowledge that discussions were had with Xxxxxxx & Xxxxxxxxx, Inc.
acting as a consultant to Tenant, and that no conversations or negotiations were
had by such party with any broker or finder concerning the renting of the
Demised Premises, only
-49-
Xxxxxxx & Xxxxxxxxx, Inc. acting as a consultant to Tenant as aforesaid. Xxxxxx
agrees to hold Landlord harmless against any claims for a brokerage commission
arising out of any conversations or any negotiations had by Xxxxxx with any
broker or finder or any consultant other than Xxxxxxx & Xxxxxxxxx, Inc. Both
parties acknowledge that Xxxxxxxx agrees to pay a consulting fee to Xxxxxxx &
Xxxxxxxxx, Inc. pursuant to a separate agreement.
ARTICLE 32
Notices
32.01 Any notice, statement, demand or other communication required or
permitted to be given, rendered or made by either party to the other, pursuant
to this lease or pursuant to any applicable law or requirement of public
authority, shall be in writing (whether or not so stated elsewhere in this
lease) and shall be deemed to have been properly given, rendered or made, if
sent by registered or certified mail, return receipt requested, addressed to the
other party at the address hereinabove set forth (except that after the
Commencement Date, Tenant's address, unless Tenant shall give notice to the
contrary, shall be the Building), and shall be deemed to have been given,
rendered or made three (3) days after the day so mailed, unless mailed outside
of the States of New Jersey or New York, in which case it shall be deemed to
have been given, rendered or made on the expiration of the normal period of time
for delivery of mail from the post-office of origin to the post-office of
destination. Either party may, by notice as aforesaid, designate a different
address or addresses for notices, statements, demand or other communications
intended for it.
A copy of all notices to Landlord shall be sent to:
Xxxxxx & Xxxxx
000 Xxxx Xxxxxx
Xxx Xxxx, Xxx Xxxx 00000
Attn: Xxxxxx Xxxxx, Esq.
A copy of all notices to Tenant shall be sent to:
Skadden, Arps, Slate, Xxxxxxx & Xxxx
000 Xxxxx Xxxxxx
Xxx Xxxx, Xxx Xxxx 00000-9931
Attn: Xxxxxxx Xxxxxxxx, Esq.
ARTICLE 33
Estoppel Certificate, Memorandum
33.01 Each party agrees, at any time and from time to time, as requested
by the other party, upon not less than ten (10) days' prior notice, to execute
and deliver to the other a statement certifying (a) that this lease is
unmodified and in full force and effect (or if there have been modifications,
that the same is in full force and effect as modified and stating the
modifications) and whether any options granted to Tenant pursuant to the
-50-
provisions of this lease have been exercised, (b) that the term of this lease
has commenced and the dates to which the fixed rent and additional rent have
been paid and the amounts thereof, (c) that Landlord has fulfilled all of its
obligations of an inducement nature, (d) that all work to be done by Landlord
has been completed, (e) that Tenant has accepted possession of the Demised
Premises and is in occupancy thereof, (f) that no advance rent in excess of one
(1) month has been paid, and (g) any other data requested by Landlord or Tenant
as the case may be relating to this lease and stating whether or not, to the
best knowledge of the party, the other party is in default in performance of any
of its obligations under this lease, and, if so, specifying each such default of
which the party may have knowledge, it being intended that any such statement
delivered pursuant hereto may be relied upon by others with whom the party
requesting such certificate may be dealing. A successor landlord (as defined in
Section 7.03) shall not be required to furnish Tenant with more than three (3)
estoppel certificates in any calendar year.
33.02 At the request of either party, Landlord and Tenant shall promptly
execute, acknowledge and deliver a memorandum with respect to this lease
sufficient for recording. Such memorandum shall not in any circumstances be
deemed to change or otherwise affect any of the obligations or provisions of
this lease.
ARTICLE 34
Arbitration
34.01 Either party may request arbitration of any matter in dispute
wherein arbitration is expressly provided in this lease as the appropriate
remedy. The party requesting arbitration shall do so by giving notice to that
effect to the other party, and both parties shall promptly thereafter jointly
apply to the American Arbitration Association (or any organization successor
thereto) in the City of New York for the appointment of a single arbitrator.
34.02 The arbitration shall be conducted in accordance with the then
prevailing rules of the American Arbitration Association (or any organization
successor thereto) in the City of New York. In rendering such decision and
award, the arbitrator shall not add to, subtract from or otherwise modify the
provisions of this lease.
34.03 If for any reason whatsoever a written decision and award of the
arbitrator shall not be rendered within sixty (60) days after the appointment of
such arbitrator, then at any time thereafter before such decision and award
shall have been rendered either party may apply to any appropriate court having
jurisdiction, by action, proceeding or otherwise (but not by a new arbitration
proceeding) as may be proper to determine the question in dispute consistently
with the provisions of this lease.
34.04 All the expenses of the arbitration shall be borne by the parties
equally.
-51-
ARTICLE 35
No Other Representations, Construction, Governing Law, Consents
35.01 Tenant expressly acknowledges and agrees that Landlord has not made
and is not making, and Tenant, in executing and delivering this lease, is not
relying upon, any warranties, representations, promises or statements, except to
the extent that the same are expressly set forth in this lease or in any other
written agreement which may be made between the parties concurrently with the
execution and delivery of this lease and shall expressly refer to and is
attached to this lease. This lease and said other written agreement(s) made
concurrently herewith are hereinafter referred to as the "lease documents". It
is understood and agreed that all understandings and agreements heretofore had
between the parties are merged in the lease documents, which alone fully and
completely express their agreements and that the same are entered into after
full investigation, neither party relying upon any statement or representation
not embodied in the lease documents, made by the other.
35.02 If any of the provisions of this lease, or the application thereof
to any person or circumstances, shall, to any extent, be invalid or
unenforceable, the remainder of this lease, or the application of such provision
or provisions to persons or circumstances other than those as to whom or which
it is held invalid or unenforceable, shall not be affected thereby, and every
provision of this lease shall be valid and enforceable to the fullest extent
permitted by law.
35.03 This lease shall be governed in all respects by the laws of the
State of New Jersey.
35.04 Except for a consent or approval under Section 9.07 hereof, wherever
in this lease Landlord's consent or approval is required, if Landlord shall
refuse such consent or approval, Tenant in no event shall be entitled to make,
nor shall Tenant make, any claim, and Tenant hereby waives any claim, for money
damages (nor shall Tenant claim any money damages by way of set-off,
counterclaim or defense) based upon any claim or assertion by Tenant that
Landlord unreasonably withheld or unreasonably delayed its consent or approval.
Tenant's sole remedy shall be an action or proceeding to enforce any such
provision, for specific performance, injunction or declaratory judgment.
ARTICLE 36
Parties Bound
36.01 The obligations of this lease shall bind and benefit the successors
and assigns of the parties with the same effect as if mentioned in each instance
where a party is named or referred to, except that no violation of the
provisions of Article 9 shall operate to vest any rights in any successor or
assignee of Tenant and that the provisions of this Article shall not be
construed as modifying the conditions of limitation contained in Article 25.
However, the obligations of Landlord under this lease shall not be binding upon
Landlord herein named with respect to any period subsequent to the transfer of
its interest in the Building as owner or lessee thereof and in event of such
transfer said obligations shall thereafter be binding upon each transferee of
the interest of Landlord
-52-
herein named as such owner or lessee of the Building, but only with respect to
the period ending with a subsequent transfer within the meaning of this Article.
36.02 If Landlord shall be an individual, joint venture, tenancy in
common, co-partnership, unincorporated association, or other unincorporated
aggregate of individuals and/or entities or a corporation, Tenant shall look
only to such Landlord's estate and property in the Building (or the proceeds
thereof) and, where expressly so provided in this lease, to offset against the
rents payable under this lease, for the satisfaction of Tenant's remedies for
the collection of a judgment (or other judicial process) requiring the payment
of money by Landlord in the event of any default by Landlord hereunder, and no
other property or assets of such Landlord or any partner, member, officer or
director thereof, disclosed or undisclosed shall be subject to levy, execution
or other enforcement procedure for the satisfaction of Xxxxxx's remedies under
or with respect to this lease, the relationship of Landlord and Tenant hereunder
or Tenant's use or occupancy of the Demised Premises. The limitations of this
Section 36.02 shall not apply to the payment of Landlord's Share of the "Work
Cost" (as defined in Exhibit C annexed hereto) or to the return of any monies
paid by Tenant as advance rent under Section 1.04(a) if Tenant is entitled to
the return of such monies.
ARTICLE 37
Certain Definitions And Construction
37.01 For the purposes of this lease and all agreements supplemental to
this lease, unless the context otherwise requires the definitions set forth in
Exhibit E annexed hereto shall be utilized.
37.02 The various terms which are italicized and defined in other Articles
of this lease or are defined in Exhibits annexed hereto, shall have the meanings
specified in such other Articles and such Exhibits for all purposes of this
lease and all agreements supplemental thereto, unless the context shall
otherwise require.
ARTICLE 38
Financing
If any lending institution with which Xxxxxxxx has negotiated or may
negotiate interim or long term financing for the Building or part thereof shall
require change(s) in this lease as a condition of its approval of this lease for
such financing, and if, within ten (10) days after notice from Landlord, Xxxxxx
fails or refuses to execute with Landlord the amendment or amendments to this
lease accomplishing the change(s) which are stated by Landlord to be needed in
connection with approval of this lease for purposes of such financing which
change(s) does (do) not increase the monetary obligations or materially increase
the other obligations or materially adversely affect the non-monetary rights of
Tenant, then Landlord shall have the right to cancel this lease at any time
prior to the Commencement Date. In the event of cancellation by Landlord
hereunder, this lease shall be and become null and void and both parties shall
automatically be released as of the date of Landlord's cancellation notice from
any and all liability or obligation under this lease, except that Landlord shall
return the security, if any, deposited by Xxxxxx.
-53-
ARTICLE 39
Right of First Refusal
39.01 Provided that this lease shall then be in full force and effect
without default on the part of the Tenant hereunder, after notice and the
expiration of any applicable grace or cure period provided herein, Tenant shall
have the right of first refusal (hereinafter referred to as the "Refusal Right")
with respect to the leasing of any space in the Building (hereinafter referred
to as the "Expansion Space"), when and if the same becomes available for further
leasing by Landlord after the initial leasing thereof, inclusive of (i) any
renewal or extension period provided in such lease for the initial leasing or
(ii) as may be agreed to between Landlord and the tenant under the initial
leasing for any term subsequent to the expiration of such initial leasing. The
Refusal Right shall be exercisable in accordance with, and shall be subject to
and governed by, the terms, covenants and conditions contained in the balance of
this Article 39.
39.02 If, after the initial leasing by Landlord and extension or renewal
thereof, as aforesaid, any Expansion Space shall subsequently become available
for leasing, Landlord shall send written notice (hereinafter referred to as an
"Availability Notice") to Tenant by certified mail, return receipt requested, if
and when Landlord shall learn that the Expansion Space shall become available
for further leasing by Landlord, which Availability Notice shall specify: (i)
the date of expected availability of the Expansion Space which shall be not less
than thirty (30) days nor more than two (2) years from the date of the
Availability Notice, and (ii) the terms ("Landlord's Terms") upon which Landlord
is willing to rent the Expansion Space. If Tenant shall desire to exercise the
Refusal Right with respect to the Expansion Space, Tenant shall send Landlord
written notice thereof (hereinafter referred to as an "Acceptance Notice") on or
before the thirtieth (30th) day next succeeding the day upon which Landlord
shall have sent the Availability Notice to Tenant.
39.03 If Tenant shall send an Acceptance Notice to Landlord in the form
and manner, and within the thirty (30) day period, referred to in Section 39.02
hereof, the parties hereto shall promptly enter into a new lease (hereinafter
referred to as the "New Lease") for the Expansion Space, which New Lease shall
contain all of the same terms, covenants and conditions contained in this lease,
except that:
(a) the term of the New Lease shall commence upon the day
(hereinafter referred to as the "New Lease Commencement Date") which shall
be the later of (i) the Availability Date or (ii) the day that possession
of the Expansion Space shall become available and shall expire upon the
day upon which the term of this lease (as the same may be renewed pursuant
to the terms of Article 40 hereof) shall expire. Xxxxxxxx agrees to
promptly commence and diligently pursue appropriate legal proceedings to
obtain possession of the Demised Premises. In the event Landlord is unable
to obtain and deliver possession of the entire Demised Premises to Tenant
within six (6) months after the Effective Date, Tenant shall have the
right upon ten (10) days' prior written notice to Landlord to cancel and
terminate this lease as of the effective date set forth in Tenant's notice
(provided Landlord has not obtained possession of the Demised Premises by
on or before the effective date set forth in Tenant's notice), whereupon
this lease shall be deemed terminated and at an end without any further
act on the part of either party with the same
-54-
force and effect as if said date were the original expiration date set
forth in the instant lease herein and neither party shall have any further
rights against each other with respect to this lease. Under no
circumstances shall Tenant be required to accept possession of any part of
the Demised Premises until Landlord shall have delivered possession of the
entire Demised Premises to Tenant.
(b) the annual fixed rent and escalation provisions contained in the
New Lease shall be those specified in Landlord's Terms or the Revised
Landlord's Terms (as hereinafter defined);
(c) Articles 3 and 4 hereof and Exhibit C hereto shall be omitted
from the New Lease, and the same shall expressly provide that: (i) except
as otherwise specified in Landlord's Terms or Revised Landlord's Terms,
Tenant shall accept the Expansion Space on the New Lease Commencement Date
in its then "as is" condition; (ii) except as otherwise specified in
Landlord's Terms or Revised Landlord's Terms, Landlord shall not be
obligated to perform, or pay the cost and expense of performing, any work
in or to the Expansion Space in order to prepare the same for Tenant's
occupancy; and (iii) if Landlord shall be unable to give possession of the
Expansion Space to Tenant on what would otherwise be the New Lease
Commencement Date because of the holding-over or retention of possession
of the Expansion Space or any part thereof by any tenant, undertenant, or
occupants, or for any other reason, Landlord shall not be subject to any
liability for failure to give possession on such date and the validity of
this lease and the New Lease shall not be impaired under such
circumstances, but the New Lease Commencement Date shall be deemed
postponed by the number of days necessary for Landlord to obtain such
possession; and
(d) Articles 39, 40, 41 and 42 hereof shall be omitted from the New
Lease.
(e) Xxxxxxxx agrees that it will enforce its rights against the
occupant of the Expansion Space to surrender possession in the condition
required under the existing lease. In the event Landlord fails to enforce
such rights against the occupant of the Expansion Space, Landlord agrees
that Tenant may do so in Landlord's name.
39.04 In the event that Tenant shall fail to send an Acceptance Notice to
Landlord in the form and manner, and within the period provided herein, referred
to in Section 39.02 hereof, such failure shall constitute a waiver of the
Refusal Right. Landlord may thereafter lease the Expansion Space to other
parties upon terms not materially more favorable to the other parties than
Landlord's Terms. If Landlord intends to revise the Landlord's Terms to make
them more favorable to other parties, Landlord shall notify Tenant of the
revisions which are more favorable ("Revised Landlord's Terms"), and Tenant
shall have an additional period of ten (10) days after receipt of the Revised
Landlord's Terms within which to send an Acceptance Notice.
-55-
ARTICLE 40
Renewal Options
40.01 (a) Provided that this lease shall be in full force and effect on
the Expiration Date without default on the part of Tenant hereunder beyond
the expiration of notice and any grace period, Tenant shall have the
option (hereinafter referred to as the "1st Renewal Option") to renew this
lease for a renewal term (hereinafter referred to as the "1st Renewal
Term") of five (5) years, to commence on the Expiration Date (hereinafter
referred to as the "1st Renewal Term Commencement Date") and to expire
five (5) years thereafter (herein referred to as the "1st Renewal Term
Expiration Date"). Tenant shall exercise the 1st Renewal Option by sending
a written notice thereof (which notice is hereinafter referred to as the
"1st Renewal Notice") to Landlord by certified mail, return receipt
requested, not less than twelve (12) months prior to the Expiration Date.
If Tenant shall send the 1st Renewal Notice within the time and in the
manner hereinbefore provided, this lease shall be deemed renewed for the
1st Renewal Term upon the terms, covenants and conditions hereinafter
contained. If Tenant shall fail to send the 1st Renewal Notice within the
time and in the manner hereinbefore provided, the 1st Renewal Option shall
cease and terminate, and Tenant shall have no further option to renew this
lease.
(b) Provided that this lease shall be in full force and effect on
the Expiration Date without default on the part of Tenant hereunder beyond
the expiration of notice and any grace period, Tenant shall have the
option (hereinafter referred to as the "2nd Renewal Option") to renew this
lease for a renewal term (hereinafter referred to as the "2nd Renewal
Term") of five (5) years, to commence on the Expiration Date (hereinafter
referred to as the "2nd Renewal Term Commencement Date") and to expire
five (5) years thereafter (herein referred to as the "2nd Renewal Term
Expiration Date"). Tenant shall exercise the 2nd Renewal Option by sending
a written notice thereof (which notice is hereinafter referred to as the
"2nd Renewal Notice") to Landlord by certified mail, return receipt
requested, not less than twelve (12) months prior to the Expiration Date.
If Tenant shall send the 2nd Renewal Notice within the time and in the
manner hereinbefore provided, this lease shall be deemed renewed for the
2nd Renewal Term upon the terms, covenants and conditions hereinafter
contained. If Tenant shall fail to send the 2nd Renewal Notice within the
time and in the manner hereinbefore provided, the 2nd Renewal Option shall
cease and terminate, and Tenant shall have no further option to renew this
lease.
40.02 The 1st Renewal Term, if any, shall be upon, and subject to, all of
the terms, covenants and conditions provided in this lease for the original term
hereof, except that:
(a) any terms, covenants, or conditions hereof that are expressly or
by their nature inapplicable to the 1st Renewal Term (including, without
limitation, Articles 3, 4 and Section 40.01(a) hereof) shall not apply
during such 1st Renewal Term;
-56-
(b) the annual Minimum Rent payable by Tenant during the 1st Renewal
Term (hereinafter referred to as the "1st Renewal Rent"), subject to
adjustment as otherwise in this lease provided, shall be an amount equal
to 90% of the fair market rental value of the Demised Premises, to be
determined as provided in Section 40.04 hereof and to be calculated as of
the 1st Renewal Term Commencement Date on the basis of a new five (5) year
letting of the Demised Premises and as if the improvements in the Demised
Premises were Building standard improvements.
40.03 The 2nd Renewal Term, if any, shall be upon, and subject to, all of
the terms, covenants and conditions provided in this lease for the original term
hereof, except that:
(a) any terms, covenants, or conditions hereof that are expressly or
by their nature inapplicable to the 2nd Renewal Term (including, without
limitation, Articles 3, 4 and 40 hereof) shall not apply during such 2nd
Renewal Term;
(b) the annual Minimum Rent payable by Tenant during the 2nd Renewal
Term (hereinafter referred to as the "2nd Renewal Rent"), subject to
adjustment as otherwise in this lease provided, shall be an amount equal
to the fair market rental value of the Demised Premises, to be determined
as provided in Section 40.04 hereof and to be calculated as of the 2nd
Renewal Term Commencement Date on the basis of a new five (5) year letting
of the Demised Premises and as if the improvements in the Demised Premises
were Building standard improvements.
40.04 In the event that Tenant shall exercise the 1st Renewal Option or
the 2nd Renewal Option, as the case may be, as provided in Section 40.01 hereof,
the 1st Renewal Rent or the 2nd Renewal Rent, as the case may be, shall be
determined jointly by Xxxxxxxx and Tenant, and such determination shall be
confirmed in a writing (hereinafter referred to as a "Rental Agreement") to be
executed in recordable form by Landlord and Tenant not later than the day
(hereinafter referred to as the "Determination Date") which shall be ninety (90)
days next preceding the Expiration Date or the 1st Renewal Term Expiration Date,
as the case may be. In the event that Landlord and Tenant shall have failed to
join in executing a Rental Agreement on or before the Determination Date because
of their failure to agree upon the 1st Renewal Rent or the 2nd Renewal Rent, as
the case may be, then the 1st Renewal Rent or the 2nd Renewal Rent, as the case
may be, shall be determined by arbitration as follows:
(a) Landlord and Tenant shall each appoint an arbitrator by written
notice given to the other party hereto not later than thirty (30) days
after the Determination Date. If either Landlord or Tenant shall have
failed to appoint an arbitrator within such period of time and thereafter
shall have failed to do so by written notice given within a period of ten
(10) days after notice by the other party requesting the appointment of
such arbitrator, then such arbitrator shall be appointed by the American
Arbitration Association or its successor (the branch office of which is
located in or closest to the City of New York) upon request of either
Landlord or Tenant, as the case may be;
(b) the two (2) arbitrators appointed as above provided shall
appoint a third (3rd) arbitrator by written notice given to both Landlord
and Tenant, and, if
-57-
they fail to do so by written notice given within thirty (30) days after
their appointment, such third (3rd) arbitrator shall be appointed as above
provided for the appointment of an arbitrator in the event either party
fails to do so;
(c) all of such arbitrators shall be real estate appraisers having
not less than ten (10) years experience in appraising the fair market
rental value of real estate similar to the Building located within the
City of Jersey City and whose appraisals are acceptable to commercial
banks, savings banks or life insurance companies doing business in the
State of New York;
(d) the three arbitrators, selected as aforesaid, forthwith shall
convene and render their decision in accordance with the then applicable
rules of the American Arbitration Association or its successor, which
decision shall be strictly limited to a determination of the Xxxxxxx Xxxx
as the case may be, within twenty (20) days after the appointment of the
third (3rd) arbitrator. The decision of such arbitrators shall be in
writing and the vote of the majority of them shall be the decision of all
and, insofar as the same is in compliance with the provisions and
conditions of this Section 40.04 and of Section 40.05 hereof shall be
binding upon Landlord and Tenant. Duplicate original counterparts of such
decision shall be sent forthwith by the arbitrators by certified mail,
return receipt requested, to both Landlord and Tenant. The arbitrators, in
arriving at their decision, shall be entitled to consider all testimony
and documentary evidence that may be presented at any hearing, as well as
facts and data which the arbitrators may discover by investigation and
inquiry outside such hearings. If, for any reason whatsoever, a written
decision of the arbitrators shall not be rendered within thirty (30) days
after the appointment of the third (3rd) arbitrator, then, at any time
thereafter before such decision shall have been rendered, either party may
apply to any court in the State of New Jersey having jurisdiction, by
action, proceeding or otherwise (but not by a new arbitration proceeding)
as may be proper, to determine the question in dispute consistently with
the provisions of this lease. The cost and expense of such arbitration,
action, proceeding, or otherwise shall be borne equally by Landlord and
Tenant.
40.05 Notwithstanding anything to the contrary contained in Section 40.04
hereof:
(a) the 1st Renewal Rent shall in no event be less than an amount
(hereinafter referred to as the "1st Renewal Minimum Rent") equal to the then
annual fixed rent and in addition thereto Tenant shall be obligated to continue
to pay the aggregate of any Tax Payment and the then current payment for
increases in Operating Expenses under Sections 5.07-5.10 hereof payable by
Tenant pursuant to the terms of Article 5 hereof for the Tax Year and the
calendar year, respectively, in which the Expiration Date shall occur, and (b)
the 2nd Renewal Rent shall in no event be less than an amount (hereinafter
referred to as the "2nd Renewal Minimum Rent") equal to the then annual fixed
rent and in addition thereto Tenant shall be obligated to continue to pay the
aggregate of any Tax Payment and the then current payment for increases in
Operating Expenses under Sections 5.07-5.10 hereof payable by Tenant pursuant to
the terms of Article 5 hereof for the Tax Year and the calendar year,
respectively, in which the Expiration Date shall occur.
-58-
40.06 In the event that Tenant shall exercise the 1st Renewal Option as
provided in Section 40.01(a) hereof and the 1st Renewal Rent shall not be
finally determined pursuant to the terms of Section 40.04 hereof on or before
the 1st Renewal Term Commencement Date then:
(a) The annual fixed rent payable by Tenant during the 1st Renewal
Term until the 1st Renewal Rent shall be so finally determined shall,
subject to adjustment as therein provided, be equal to the 1st Renewal
Minimum Rent; and
(b) In the event that the 1st Renewal Rent as finally determined
pursuant to the terms of Section 40.04 hereof, shall be greater than the
1st Renewal Minimum Rent (i) the annual fixed rent payable by Tenant for
the balance of the 1st Renewal Term shall be and become the 1st Renewal
Rent as finally determined, and (ii) Tenant shall forthwith pay to
Landlord an amount equal to the difference between (x) the sum of the
actual rental payments paid to Landlord during the 1st Renewal Term before
such final determination and (y) the sum of the rental payments that
Tenant would have paid to Landlord if the 1st Renewal Rent was finally
determined prior to the 1st Renewal Term Commencement Date.
40.07 In the event that Tenant shall exercise the 2nd Renewal Option as
provided in Section 40.01(a) hereof and the 2nd Renewal Rent shall not be
finally determined pursuant to the terms of Section 40.04 hereof on or before
the 2nd Renewal Term Commencement Date then:
(a) The annual fixed rent payable by Tenant during the 2nd Renewal
Term until the 2nd Renewal Rent shall be so finally determined shall,
subject to adjustment as therein provided, be equal to the 2nd Renewal
Minimum Rent; and
(b) In the event that the 2nd Renewal Rent as finally determined
pursuant to the terms of Section 40.04 hereof, shall be greater than the
2nd Renewal Minimum Rent (i) the annual fixed rent payable by Tenant for
the balance of the 2nd Renewal Term shall be and become the 2nd Renewal
Rent as finally determined, and (ii) Tenant shall forthwith pay to
Landlord an amount equal to the difference between (x) the sum of the
actual rental payments paid to Landlord during the 2nd Renewal Term before
such final determination and (y) the sum of the rental payments that
Tenant would have paid to Landlord if the 2nd Renewal Rent was finally
determined prior to the 2nd Renewal Term Commencement Date.
ARTICLE 41
Option with Respect to the 10th Floor
41.01 Provided Tenant is not then in default hereunder after notice and
beyond the expiration of any grace period, Tenant shall have the right by notice
(the "Election Notice") given on or before the fourth anniversary of the
Commencement Date to include in the Demised Premises the 10th Floor of the
Building (the "10th Floor Space"), such inclusion to be effective as of the
fifth anniversary of the Commencement Date (the "Effective Date").
-59-
41.02 In the event Tenant shall duly elect by giving the Election Notice
to include the 10th Floor Space in the Demised Premises as provided above, then
the Fixed Rent shall be increased as of the applicable Effective Date by an
amount equal to $660,520.80 per year ($55,043.40 per month) for the period
commencing on the fourth (4th) anniversary of the Commencement Date and ending
on the day next preceding the Effective Date and thereafter at the per rentable
square foot rental rates payable hereunder. Tenant's Proportionate Share, as
specified in Section 5.01(e) shall be increased by 5.76% (which has been
computed by dividing the agreed rentable square foot area of the 10th Floor
Space (35,820) by the Building Area and which shall be subject to recomputation
if the Building Area shall be increased) and Tenant's Operational Proportionate
Share as specified in Section 5.07(k) shall be increased by 5.83% (which has
been computed by dividing the agreed rentable square foot area of the 10th Floor
Space (35,820) by the Building Office Area and shall be subject to recomputation
if the Building Office Area shall be increased).
41.03 Tenant shall accept delivery of the 10th Floor Space in its then
existing "as is" condition, it being agreed that Landlord shall have no
obligation to perform any work or refurbishing of such space in connection with
Tenant's occupancy thereof, provided, however, that the 10th Floor Space will
either (A) have an existing installation by or on behalf of a previous tenant or
occupant, which Xxxxxx agrees to accept in its then "as is" condition, or (B) if
the 10th Floor Space shall not have been furnished with an installation by or on
behalf of an existing tenant or occupant, then Landlord will pay to Tenant an
amount equal to the product of (i) $17.00, multiplied by (ii) the rentable
square foot area of space not so furnished with an installation, which sum shall
be used by Tenant in connection with the furnishing of an installation in such
space. Xxxxxxxx agrees that it will enforce its rights against the occupant of
the 10th Floor Space to surrender possession in the condition required under the
existing 10th Floor lease. In the event Landlord fails to enforce such rights
against the occupant of the 10th Floor Space, Landlord agrees that Tenant may do
so in Landlord's name. In no event will the Effective Date occur prior to the
ninetieth (90) day after notice to Tenant of the availability of such space.
41.04 Landlord shall attempt to initially lease the 10th Floor Space for
terms ending respectively on or about the intended Effective Date. Promptly
after executing a lease on the 10th Floor Space, Landlord shall notify Tenant of
the fact that such lease has been executed and the term thereof. Xxxxxx agrees,
however, to accept such space, if Tenant shall give the Election Notice with
respect thereto, at any time during the two (2) year period commencing one (1)
year before such Effective Date and ending one (1) year after such Effective
Date, to allow for the fact that the term of such initial leasing may not expire
precisely on the Effective Date. In any event, if Landlord fails or is unable to
deliver all or any portion of the 10th Floor Space to Tenant on the Effective
Date therefor due to the holding over of the prior tenant or otherwise, same
shall not be deemed actually included within the Demised Premises, and the Fixed
Rent and Additional Rent applicable thereto shall not commence (with respect to
such portion thereof that shall not be timely delivered) until the date on which
same is delivered to Tenant. Except for such delay in the commencement of
rental, Landlord shall have no liability to Tenant for failure to deliver such
space, provided, however, that Landlord agrees to use reasonable diligence to
obtain possession of any such space as soon as possible, including, without
limitation, the commencement of an action or proceeding to obtain possession of
such space if, in Landlord's reasonable judgment, such action or proceeding is
deemed appropriate. Xxxxxxxx agrees to promptly commence and diligently pursue
appropriate
-60-
legal proceedings to obtain possession of the 10th Floor Space. In the event
Landlord is unable to obtain and deliver possession of the entire 10th Floor
Space to Tenant within six (6) months after the Effective Date, Tenant shall
have the right upon ten (10) days' prior written notice to Landlord to cancel
and terminate the Election Notice as of the effective date set forth in Tenant's
notice (provided Landlord has not obtained possession of the 10th Floor Space
by, on or before the effective date set forth in Tenant's notice), whereupon the
Election Notice shall be deemed terminated and at an end without any further act
on the part of either party, and neither party shall have any further rights
against each other with respect to the 10th Floor Space. Under no circumstances
shall Tenant be required to accept possession of any part of the 10th Floor
Space until Landlord shall have delivered possession of the entire 10th Floor
Space to Tenant.
41.05 In the event that within thirty (30) months after the Commencement
Date Landlord has been unable to lease the 10th Floor Space to a third party,
Landlord may elect at any time thereafter to send a notice to Tenant (the "10th
Floor Put") wherein Landlord directs Tenant to send an Election Notice within
thirty (30) days after the date of the 10th Floor Put. In the event that Tenant
sends the Election Notice in response to the 10th Floor Put, the effective date
for the payment of increased rental in such event (the "Put Rent C.D.") shall be
ninety (90) days after the date of the 10th Floor Put and the other provisions
of this Article 41 shall be in effect as to the 10th Floor Space and the rental
shall be at the rate of (x) $615,029.40 per year ($51,252.45 per month) for the
period commencing on the Put Rent C.D. and ending on the day next preceding the
third (3rd) anniversary of the Commencement Date; (y) $637,954.20 per year
($53,162.85 per month) for the period commencing on the third (3rd) anniversary
of the Commencement Date and ending on the day next preceding the fourth (4th)
anniversary of the Commencement Date; and (z) $660,520.80 per year ($55,043.40
per month) for the period commencing on the fourth (4th) anniversary of the
Commencement Date and ending on the day next preceding the Effective Date and
thereafter at the per rentable square foot rental rates payable hereunder.
41.06 In the event that Xxxxxx fails to send an Election Notice as herein
provided, Xxxxxx's option with respect to the 10th Floor Space shall be deemed
forever waived.
ARTICLE 42
Option with Respect to the 11th Floor
42.01 Provided Tenant is not then in default hereunder beyond the
expiration of notice and any grace period, Tenant shall have the option (the
"11th Floor Option") to lease the 11th Floor of the Building from Landlord for a
period (the "11th Floor Term") commencing ten (10) years after the Commencement
Date (the "11th Floor Effective Date") and expiring on the Expiration Date. In
the event the Tenant shall desire to exercise the 11th Floor Option, Tenant
shall send written notice thereof (hereinafter referred to as the "11th Floor
Notice") to Landlord by certified mail, return receipt requested, on or before
the earlier of (a) the ninth anniversary of the Commencement Date, or (b) if
after the initial leasing of the 11th Floor by Landlord, the 11th Floor becomes
available for reletting and Landlord notifies Tenant that the 11th Floor will be
available for Tenant's possession prior to the 11th Floor Effective Date but not
earlier than two (2) years before the Effective Date, then within ninety (90)
days after Landlord notice to Tenant thereof.
-61-
42.02 Tenant shall accept delivery of the 11th Floor Space in its then
existing "as is" condition, it being agreed that Landlord shall have no
obligation to perform any work or refurbishing of such space in connection with
Tenant's occupancy thereof, provided, however, that the 11th Floor Space will
either (A) have an existing installation by or on behalf of a previous tenant or
occupant, which Xxxxxx agrees to accept in its then "as is" condition, or (B) if
the 11th Floor Space shall not have been furnished with an installation by or on
behalf of an existing tenant or occupant, then Landlord will pay to Tenant an
amount equal to the product of (i) $17.00, multiplied by (ii) the rentable
square foot area of space not so furnished with an installation, which sum shall
be used by Tenant in connection with the furnishing of an installation in such
space. Xxxxxxxx agrees that it will enforce its rights against the occupant of
the 11th Floor to surrender possession in the condition required under its
existing lease. In the event Landlord fails to enforce such rights against the
occupant of the 11th Floor, Landlord agrees that Tenant may do so in Landlord's
name.
42.03 Landlord shall attempt to initially lease the 11th Floor Space for
terms ending respectively on or about the intended Effective Date. Xxxxxx
agrees, however, to accept such space, if Tenant shall give the 11th Floor
Notice with respect thereto, at any time during the four (4) year period
commencing two (2) years before such Effective Date and ending two (2) years
after such Effective Date, to allow for the fact that the term of such initial
leasing may not expire precisely on the 11th Floor Effective Date. Landlord
agrees that it will enforce its rights to the occupant of the Expansion Space to
surrender possession in the condition required under its then existing lease. In
the event Landlord fails to enforce such rights against the occupant of the
Expansion Space Landlord agrees that Tenant may do so in Landlord's name. In no
event will the Effective Date occur prior to the ninetieth (90th) day after
notice to Tenant of the availability of such space.
42.04 If Tenant shall send the 11th Floor Notice to Landlord within the
time and in the manner set forth in Section 42.01 hereof, the parties hereto
shall, promptly after the 11th Floor Fixed Rent (as such term is hereinafter
defined) shall be determined in accordance with Section 42.05 hereof, enter into
a new lease (hereinafter referred to as a "11th Floor Lease") for the 11th
Floor, which 11th Floor Lease shall contain all of the same terms, covenants and
conditions contained in this lease, except that:
(i) The term of the 11th Floor Lease shall (i) commence upon a day
(hereinafter referred to as the "11th Floor Commencement Date") which
shall be the earlier of (i) the 11th Floor Effective Date or (ii) if
notice has been given by Landlord pursuant to Section 42.01(b) then
ninety (90) days from the date of Landlord's notice under Section 42.01
and shall expire upon the Expiration Date;
(ii) The annual fixed rent to be payable by Tenant pursuant to the
11th Floor Lease (herein referred to as the "11th floor Fixed Rent")
shall, subject to adjustment as therein provided, be an amount equal to
ninety (90%) percent of the fair market rental value of the 11th Floor, to
be determined as provided in Section 42.05 hereof and to be calculated as
of the 11th Floor Commencement Date on the basis of a new letting of the
11th Floor for a term equal to the 11th Floor Term;
-62-
(iii) Article 3 hereof shall be omitted from the 11th Floor Lease,
and the same shall contain, in lieu thereof, the following language:
"3.01 If Landlord is unable to give possession of the Demised
Premises on the Commencement Date because of the holding-over or
retention of possession of any tenant, undertenant or occupants, or
for any other reason, Landlord shall not be subject to any liability
for failure to give possession on said date and the validity of this
lease shall not be impaired under such circumstances, nor shall the
same be construed in any wise to extend the term of this lease, but
the rent and additional rent payable hereunder shall be abated
(provided Xxxxxx is not responsible for the inability to obtain
possession) until after Landlord shall have given Tenant written
notice that the Demised Premises are substantially ready for
Tenant's occupancy and shall have delivered possession thereof.
Xxxxxxxx agrees to promptly commence and diligently pursue
appropriate legal proceedings to obtain possession of the Demised
Premises. In the event Landlord is unable to obtain and deliver
possession of the entire Demised Premises to Tenant within six (6)
months after the Effective Date, Tenant shall have the right upon
ten (10) days' prior written notice to Landlord to cancel and
terminate this lease as of the effective date set forth in Tenant's
notice (provided Landlord has not obtained possession of the Demised
Premises by on or before the effective date set forth in Tenant's
notice), whereupon this lease shall be deemed terminated and at an
end without any further act on the part of either party with the
same force and effect as if said date were the original expiration
date set forth in the instant lease herein and neither party shall
have any further rights against each other with respect to this
lease. Under no circumstances shall Tenant be required to accept
possession of any part of the Demised Premises until Landlord shall
have delivered possession of the entire Demised Premises to Tenant."
(iv) Article 4 hereof and Exhibit C hereto shall be omitted from the
11th Floor Lease;
(v) All references to "Commencement Date" shall be deemed to refer
to the 11th Floor Commencement Date;
(vi) "Tenant's Proportionate Stare", as such term is used in Section
5.01(e) hereof, shall be 5.71%, which shall be subject to recomputation in
the event the Building Area is increased;
(vii) "Tenant's Operational Proportionate Stare", as such term is
used in Section 5.07(k) hereof, shall be 5.77%, which shall be subject to
recomputation in the event the Building Office Area is increased;
(viii) The agreed rentable square foot area of the 11th Floor shall
be 35,504 square feet;
-63-
(ix) Articles 39, 41, 42 and 43 shall be omitted from the New Lease;
(x) A provision will be inserted that a default under the 11th Floor
Lease shall be deemed a default under this lease and vice versa.
42.05 In the event that Tenant shall exercise the 11th Floor Option as
provided in Section 42.01 hereof, then promptly thereafter Landlord and Tenant
shall attempt to agree upon the 11th Floor Fixed Rent. In the event that
Landlord and Tenant have failed to agree upon a fixed rent within ninety (90)
days after the date of the 11th Floor Notice (the "11th Floor Agreement Date"),
then the 11th Floor Fixed Rent shall be determined by arbitration as follows:
(i) Landlord and Tenant shall each appoint an arbitrator by
written notice given to the other party hereto not later than thirty
(30) days after the 11th Floor Agreement Date. If either Landlord or
Tenant shall have failed to appoint an arbitrator within such period
of time and thereafter shall have failed to do so by written notice
given within a period of five (5) days after notice by the other
party requesting the appointment of such arbitrator, then such
arbitrator shall be appointed by the American Arbitration
Association or its successor (the branch office of which is located
in or closest to the City of Jersey City), upon request of either
Landlord or Tenant, as the case may be;
(ii) the two (2) arbitrators appointed as above provided shall
attempt to reach an agreement as to the fair market rental value of
the 11th Floor, and in the event they are unable to do so within
thirty (30) days after their joint appointment, then they shall
appoint a third (3rd) arbitrator by written notice given to both
Landlord and Tenant, and, if they fail to do so by written notice
given within sixty (60) days after their appointment, such third
(3rd) arbitrator shall be appointed as above provided for the
appointment of an arbitrator in the event either party fails to do
so;
(iii) all of such arbitrators shall have the qualifications
set forth in Section 40.04;
(iv) the three arbitrators, selected as aforesaid, forthwith
shall convene and render their decision in accordance with the then
applicable rules of the American Arbitration Association or its
successor, which decision shall be strictly limited to a
determination of the fair market rental value of the 11th Floor
within twenty (20) days after the appointment of the third (3rd)
arbitrator. The decision of such arbitrators shall be in writing and
the vote of the majority of them shall be the decision of all and,
insofar as the same is in compliance with the provisions and
conditions of this Section 42.05 and of Section 42.06 hereof shall
be binding upon Landlord and Tenant. Duplicate original counterparts
of such decision shall be sent forthwith by the arbitrators by
certified mail, return receipt requested, to both Landlord and
Tenant. The arbitrators, in arriving at their decision, shall be
entitled to consider all testimony and documentary evidence that may
be presented at any hearing, as well as facts and data which the
-64-
arbitrators may discover by investigation and inquiry outside such
hearings. If, for any reason whatsoever, a written decision of the
arbitrators shall not be rendered within twenty (20) days after the
appointment of the third (3rd) arbitrator, then, at any time
thereafter before such decision shall have been rendered, either
party may apply to any court in the City of Jersey City having
jurisdiction, by action, proceeding or otherwise (but not by a new
arbitration proceeding) as may be proper, to determine the question
in dispute consistently with the provisions of this lease. The cost
and expense of such arbitration, action, proceeding, or otherwise
shall be borne equally by Landlord and Tenant.
42.06 Notwithstanding anything contained in Section 42.05 hereof, the 11th
Floor Fixed Rent shall in no event be less than an amount equal to $882,274.40
per annum ($73,522.87 per month).
42.07 In the event that Xxxxxx fails to send an Election Notice as herein
provided, Xxxxxx's option with respect to the 11th Floor Space shall be deemed
forever waived.
ARTICLE 43
Name of Building
43.01 Landlord agrees and acknowledges that (a) the name of the Building,
when completed, will be "International Financial Tower", and (b) Landlord is
endeavoring to utilize the post office address "One Pershing Plaza" for the
Building which utilization is subject to the approval of the United States
Postal Service. Landlord reserves the right to use another name for the Building
and to change the name of the Building, provided, however, that Landlord shall
not designate the name of the Building for another Building tenant. Tenant shall
be permitted at its sole cost and expense and subject to compliance with
applicable law to (a) erect a sign at such location just outside the entrance
door of the Building as Landlord shall direct (b) install a sign above the
elevator bank servicing the Demised Premises and (c) install a directory in the
lobby of the Building, all of which shall be subject to the prior written
approval of Landlord as to size, materials, quality, design, color, location (in
the case of (b) and (c)) and method of attachment, which approval shall not be
unreasonably withheld or delayed.
ARTICLE 44
Definitions
44.01 "Data Center" shall mean the space of approximately 32,800 square
feet located on the third (3rd) floor of the Building.
44.02 "Agreed Rate" shall mean two (2%) percent above the prime rate
charged from time to time by Chase Manhattan Bank, N.A., Citibank or other
similar lending institutions to its most favorite clients.
44.03 "business days" shall mean all days, excluding Saturdays, Sundays
and all days observed by the labor unions servicing the Building as legal
holidays.
-65-
ARTICLE 45
Loading Dock, Storage Space, Parking Spaces
and Communication Link
45.01 Landlord agrees that Tenant shall have use of one loading dock
("Tenant's Exclusive Loading Dock") which shall be secured to prevent access
thereto by any other party. Tenant shall, throughout the term of this lease,
keep the Tenant's Exclusive Loading Dock in good order and condition and make
any necessary repairs thereto.
45.02 Landlord agrees to demise to Tenant storage space of between 8,000
to 10,000 square feet (the "Storage Area"). Tenant agrees that the rental
payable for the Storage Area throughout the term of the lease shall be computed
at the rate of $10.00 per square foot. Promptly after the Storage Area may be
located on Landlord's Plans and Specifications for the Building, this lease
shall be amended to indicate the Storage Area and the exact rental to be paid by
Tenant therefor but Landlord shall not be obligated to furnish any services to
the Storage Area.
45.03 Landlord agrees that throughout the term of this lease, Tenant shall
have the use, free of charge of 50 parking spaces (the "Free Spaces") in the
garage servicing the Building. In addition to the Free Spaces, Tenant shall have
the right to lease an additional 150 parking spaces in the garage servicing the
Building at the same rate charged to other tenants of the Building. Xxxxxxxx
agrees to permit Tenant to use a portion of the garage, free of charge, (not
more than three car spaces) for the installation of an electrical generator
servicing the Demised Premises. Tenant shall, at its own cost and expense,
maintain the area of the garage in which the generator is located.
45.04 Subject to Landlord's prior consent which Landlord agrees not to
unreasonably withhold or delay, Tenant may install (i) a micro-wave relay or
other piece of communication equipment necessary or desirable to service the
Demised Premises (the "Communication Link") on the roof of the Building and/or
(ii) within the Building, fiber optic cables and other state of the art
communications and telecommunications equipment and facilities (the "Building
Communication Equipment"). The installation of the Communication Link and/or
Building Communication Equipment, as the case may be, shall be subject to the
following conditions:
(a) Prior to the installation, Tenant shall notify Landlord of
(i) in the case of the Communication Link, the nature of the
Communication Link, the weight, height and electrical requirements
thereof and the effect, if any, the operation of the Communication
Link will have on the radio, telephone, television or communication
reception or transmission of other tenants in the Building. Landlord
may refuse to grant consent in the event the installation and
operation of the Communication Link will, in Landlord's reasonable
opinion, adversely affect other tenants of the Building;
(ii) in the case of the Building Communication Equipment, the
nature of the Building Communication Equipment, the electrical
requirements thereof, the proposed method of installation in the
Building,
-66-
and the effect, if any, (x) the installation of the Building
Communication Equipment will have on the Building structure and
systems and (y) the operation of the Building Communication
Equipment will have on the radio, television or communication
reception or transmission of other tenants in the Building.
Additionally, Tenant shall submit to Landlord detailed plans and
specifications for the installation of the Building Communication
Equipment for Landlord's review and approval, which approval may be
withheld by Landlord in the event Landlord determines in good faith
that the installation of the Building Communication Equipment will
adversely affect the Building structure or the operations of the
Building systems. Landlord may also refuse to grant consent in the
event the installation and operation of the Building Communication
Equipment will, in Landlord's reasonable opinion, adversely affect
other tenants of the Building.
(b) The installation and operation of the Communication Link or the
Building Communication Equipment, as the case may be, shall be performed
by Tenant at Tenant's own cost and expense and in compliance with all
laws, orders, ordinances and requirements of governmental authorities
having jurisdiction thereof.
(c) Tenant shall, at Xxxxxx's own cost and expense, procure and
maintain such permits or licenses as may be necessary for the installation
and operation of the Communication Link or the Building Communication
Equipment, as the case may be.
(d) Tenant shall repair any damage to (i) the roof caused by the
installation and operation of the Communication Link or the removal
thereof, and (ii) any part of the Building or the Building systems caused
by the installation and operation of the Building Communication Equipment
or the removal thereof.
(e) Xxxxxx agrees to indemnify and hold Landlord harmless from any
claim that may be made against Landlord arising out of the installation or
operation of the Communication Link or the Building Communication
Equipment, as the case may be.
44.05 Any dispute which may arise between the parties with respect to the
meaning or application of any of the provisions of this Article 45 shall be
determined by arbitration in the manner provided in Article 34 hereof.
ARTICLE 46
Landlord's Restriction on Retail Space
46.01 Landlord shall not permit the Retail Space or any part thereof to be
used (i) as an employment agency, executive search firm or similar enterprise,
labor union, school, or vocational training center; (ii) as a xxxxxx shop or
beauty salon other than a first-class xxxxxx shop or beauty salon; (iii) as a
McDonald's, Wendy's, Xxxxxx-Xxxx or similar "fast-food" restaurant; (iv) as a
video sales or rentals store; (v) as an off-tract betting parlor or similar
enterprise; (vi) as a movie theatre; or (vii) as a discount retail store.
-67-
IN WITNESS WHEREOF, Landlord and Xxxxxx have duly executed this lease as
of the day and year first above written.
LANDLORD:
GROVE STREET ASSOCIATES OF JERSEY CITY
LIMITED PARTNERSHIP
By: Grove Street Urban Renewal Corp.,
a general partner
By: /s/ [ILLEGIBLE]
------------------------------------
Name:
Title: [ILLEGIBLE]
TENANT:
DLJ SECURITIES CORPORATION
By: /s/ [ILLEGIBLE]
------------------------------------
-68-
ACKNOWLEDGMENTS
STATE OF NEW YORK )
) ss.:
COUNTY OF NEW YORK )
On the 1 day of July, 1987, before me personally came Xxxx Xxxxx, to me
known to be the individual who executed the foregoing instrument; and, who,
being duly sworn by me, did depose and say that he resides at 00 Xxxxxxxxxx Xx,
Xxxxxxxxx, XX; that he is the President of GROVE STREET URBAN RENEWAL CORP., the
corporation described in and which executed the foregoing instrument as the
general partner of GROVE STREET ASSOCIATES OF JERSEY CITY, a New Jersey
partnership, that he knows the seal of said corporation; that the seal affixed
to said instrument is such corporate seal; that it was so affixed by order of
the Board of Directors of said corporation; and, that he signed his name thereto
by like order.
/s/ X. Xxxxxxx
---------------------------
Notary Public
XXXX XXXXXXX
Notary Public, State of New York
No. 00-0000000
Qualified in New York County
Commission Expires Feb. 17, 1988
STATE OF NEW YORK )
) ss.:
COUNTY OF NEW YORK )
On this 1 day of July, 1987, , before me personally came Xxxxxxx X.
Xxxxxxx, to me known, who being by me duly sworn, did depose and say that he
resides in 3 Magnolia Pl, Summit, NJ; that he is the [ILLEGIBLE] of DLJ
SECURITIES CORPORATION, the corporation described in and which executed the
foregoing instrument, as Tenant, and that he signed his name thereto by order of
the Board of Directors of said corporation.
/s/ X. Xxxxxxx
---------------------------
Notary Public
XXXX XXXXXXX
Notary Public, State of New York
No. 00-0000000
Qualified in New York County
Commission Expires Feb. 17, 1988
-69-
EXHIBIT A
DESCRIPTION OF THE PREMISES
BEGINNING at a point on the southerly right-of-way line of Grove Street
where the northerly right-of-way line of Xxxxx Street intersects it, as shown on
a map entitled "Boundary and Topographic Survey, Grove Street Property, Block
203, Lots 1 Thru 27, Jersey City, Xxxxxx County, N.J.," Sheet 1 of 1, prepared
by Xxxxxxxx & Xxxxx Engineering Co., and dated December 5, 1985.
1) N. 37(degree)-45' E, 210.00 feet along the southerly line of Grove
Street to the southerly line of Xxxxxxxxxxx Xxxxxxxx Drive; thence,
2) Along the southerly line of Xxxxxxxxxxx Xxxxxxxx Drive, S
52(degree)-15'-00" E, 308.82 feet to the westerly line of Newark
Avenue; thence,
3) Along the westerly line of Newark Avenue, S 25(degree)-36'-37" E,
135.44 feet to the northerly line of Xxxxxxxxx Street; thence,
4) Along the northerly line of Xxxxxxxxx Street, S 64(degree)-23'-33"
W, 167.00 feet to the northerly line of Xxxxx Street; thence,
5) Along the northerly line of Xxxxx Street, N 52(degree)-15'-00" W,
355.00 feet to the point of beginning.
The above described area encompasses Block 203, Lots 1 through 27, on the
Tax Map of the City of Jersey City.
Exh.A-Page-1-
Grove Street Associates of Jersey
City Limited Partnership
00 Xxxxxxxx Xxxxx
Xxxxxxxx, Xxx Xxxxxx 00000
July 1, 1987
DLJ Securities Corporation
000 Xxxxxxxx
Xxx Xxxx, Xxx Xxxx 00000
Re: International Financial Tower
Grove Street
Jersey City, New Jersey (the "Premises")
Gentlemen:
We are this day entering into a certain Agreement of Lease ("Lease")
and a certain Agreement of Limited Partnership of Pershing Plaza Urban Renewal
Limited Partnership ("Partnership Agreement") with respect to the development
and leasing of certain premises to be known as the International Financial
Tower, Jersey City, New Jersey. This letter is intended to set forth our
understanding as to certain provisions relating to the Lease. All capitalized
terms used in this letter which are not separately defined herein shall have the
meaning given to any such terms in the Lease.
1. DLJ Securities Corporation ("DLJ") hereby exercises its option to
include in the Demised Premises the 10th Floor of the Building, such inclusion
to be effective as of the date hereof. Simultaneously with the execution of this
letter agreement, each party shall execute and deliver to the other four (4)
counterparts of the First Amendment to Lease in the form annexed hereto as
Exhibit A. In addition, and as set forth in said First Amendment, the Option
with Respect to the 10th Floor and the Option with Respect to the 11th Floor de-
DLJ Securities Corporation
July 1, 1987
Page Two
scribed in the Lease at Article 41 and Article 42, respectively, shall be deemed
to mean the Option with Respect to the 11th Floor and Option with Respect to the
12th Floor.
2. Notwithstanding anything to the contrary contained in the Lease,
the undersigned hereby acknowledges and agrees that DLJ shall not be obligated
to pay any "fixed rent" with respect to the Demised Premises for the sixth month
in each of the second, third and fourth years of the lease term, as measured
from the Rent Commitment Date in accordance with the provisions of Article 1 of
the Lease.
3. The undersigned hereby agrees that in the event Landlord fails to
deliver to DLJ possession of either the Data Center by the Data Center Delivery
Date or the remainder of the Demised Premises by the Initial Space Delivery
Date, then in respect of the period from May 1, 1989 until the Rent Commencement
Date, the undersigned shall indemnify and hold DLJ and its Affiliates harmless
from and against any and all liability, claim, damage, cost or expense
(including attorneys' fees and disbursements) that DLJ or its Affiliates may
incur by reason of the claims of the landlord under the 120 Broadway Lease (as
hereinafter defined) in connection with the failure of DLJ or its Affiliates to
surrender and vacate its leased premises (containing approximately 190,000
square feet) at 120 Broadway, New York, New York (the "120 Broadway Lease") by
April 30, 1989, including, without limitation, the sum of all rental,
escalation, interest, penalty and other charges due under the 120 Broadway
Lease from and after May 1, 1989 which are in excess of rental charges due under
the 120 Broadway Lease as of April 30, 1989. DLJ agrees that in the event that
any such claim shall be made or action or proceeding instituted against it or an
Affiliate, DLJ will notify the undersigned thereof and shall continue to give
the undersigned notice of all developments in connection therewith within DLJ's
knowledge. Further, DLJ agrees that it shall not settle any such claim without
the consent of the undersigned. The undersigned shall defend any such claim,
action or proceeding (collectively, "Action"), at the undersigned sole cost and
expense, in the name of DLJ or its Affiliate, as the case may be, and
DLJ Securities Corporation
July 1, 1987
Page Three
shall keep DLJ advised of all proceedings relating thereto. The undersigned
shall conduct all proceedings with respect to the Action with due diligence and
shall select counsel reasonably satisfactory to DLJ.
4. The undersigned hereby agrees as an inducement to DLJ to execute
and deliver the Lease, the Partnership Agreement and this letter agreement that
in the event the undersigned shall attempt to sell, assign or otherwise Transfer
(as such term is defined in the Partnership Agreement) its interest in and to
the Premises that the undersigned shall deliver a copy of this agreement to any
such prospective purchaser or transferee (collectively "transferee"). Further,
as a condition to any such Transfer, the undersigned shall cause such transferee
to expressly assume all of the obligations of Landlord contained herein and in
the Lease.
5. Upon the closing of the Construction Loan (as defined in the
Partnership Agreement), the undersigned shall deliver to DLJ a written guaranty
with respect to the completion of the improvements at the Premises in
substantially the same form as the guaranty, if any, required to be delivered to
the Construction Lender (as defined in the Partnership Agreement) pursuant to
the Construction Loan.
6. The provisions hereof shall be binding upon and inure to the
benefit of the respective parties hereto and their successors and assigns.
7. This letter may not be changed orally but only by a written
agreement signed by the parties hereto.
DLJ Securities Corporation
July 1, 1987
Page Four
If the foregoing accurately reflects our understanding, kindly
execute the enclosed copy of this letter and return the same to the undersigned.
Very truly yours,
GROVE STREET ASSOCIATES
OF JERSEY CITY
LIMITED PARTNERSHIP
By: Grove Street Urban
Renewal Corp.,
General Partner
By: /s/ [ILLEGIBLE]
----------------------------------
(Vice) President
Acknowledged and Agreed to
this 1st day of July, 1987:
DLJ SECURITIES CORPORATION
By: /s/ Xxxxxxx X. Xxxxxxx
----------------------------------
Xxxxxxx X. Xxxxxxx,
Chairman, Financial Services Group