EXHIBIT 10.5
EXECUTION COPY
_____________________________________
PAC
_____________________________________
PROJECT DEVELOPMENT
AND
CONSTRUCTION CONTRACT
BETWEEN
TYCO SUBMARINE SYSTEMS LTD.
AND
PAN AMERICAN CROSSING LTD.
_____________________________________
DATED AS OF JULY 21, 1998
_____________________________________
TABLE OF CONTENTS
GENERAL TERMS AND CONDITIONS
Article PAGE
------- ----
1 Provision of System.................................................. 1
2 Documents Forming the Entire Contract................................ 2
3 Definitions.......................................................... 2
4 Contract Price....................................................... 15
5 Terms of Payment by Purchaser........................................ 18
6 Contract Variations.................................................. 22
6A. Optional Upgrades.................................................... 23
6B Optional System...................................................... 29
6C Optional Branching Unit.............................................. 30
6D Xxxx'x Crossing...................................................... 30
6E Alternate Mexico Configuration; Alternate Mexico Configuration Option 31
7 Responsibilities for Permits......................................... 32
8 Route Survey......................................................... 34
9 Acceptance........................................................... 34
10 Warranty............................................................. 37
11 Contractor Support................................................... 41
12 Purchaser's Obligations.............................................. 41
13 Termination for Default.............................................. 42
14 Termination for Convenience.......................................... 44
15 Suspension........................................................... 46
i
Article PAGE
------- ----
16 Title and Risk of Loss............................................... 47
17 Force Majeure........................................................ 47
18 Intellectual Property................................................ 48
19 Infringement......................................................... 53
20 Safeguarding of Information and Technology........................... 55
21 Export Control....................................................... 55
22 Liquidated Damages................................................... 56
23 Limitation of Liability/Indemnification.............................. 56
24 Counterparts......................................................... 58
25 Design and Performance Responsibility................................ 58
26 Product Changes...................................................... 58
27 Risk and Insurance................................................... 58
28 Plant and Work Rules................................................. 61
29 Right of Access...................................................... 61
30 Quality Assurance.................................................... 63
31 Documentation........................................................ 63
32 Training............................................................. 63
33 Settlement of Disputes/Arbitration/Litigation........................ 63
34 Applicable Law....................................................... 65
35 Notices.............................................................. 65
36 Publicity and Confidentiality........................................ 66
37 Assignment; Subcontractors........................................... 67
38 Relationship of the Parties.......................................... 68
39 Successors Bound..................................................... 68
ii
Article PAGE
------- ----
40 Article Captions..................................................... 68
41 Severability......................................................... 68
42 *.................................................................... 68
43 Survival of Obligations.............................................. 69
44 Non-Waiver........................................................... 69
45 Language............................................................. 69
46 Entire Agreement..................................................... 69
EXHIBITS
--------
Exhibit A................................................................. *
Exhibit B........................................................... Consent and Agreement
Exhibit C.............................................................. Opinion of Counsel
Exhibit D................................................................ Escrow Agreement
Exhibit E......................................................... Approved Subcontractors
Exhibit F........................................................... Intellectual Property
* Material omitted and separately filed with the Commission under an application
for confidential treatment.
iii
PROJECT DEVELOPMENT AND
CONSTRUCTION CONTRACT
BETWEEN
TYCO SUBMARINE SYSTEMS LTD. AND
PAN AMERICAN CROSSING LTD.
This Project Development and Construction Contract ("Contract") is
made as of this 21st day of July 1998 between Tyco Submarine Systems Ltd., a
corporation organized and existing under the laws of the State of Delaware,
United States, ("TSSL" or "Contractor") and Pan American Crossing Ltd., a
company organized and existing under the laws of Bermuda (hereinafter referred
to as "Purchaser").
WHEREAS, Purchaser desires to establish a fiber optic submarine cable
system, to be known as the Pan American Crossing Submarine Cable System
(hereinafter, and as more fully defined herein, the "System"), which will be
used to provide service between the United States, Mexico and Panama; and
WHEREAS, subject to the provisions of Article 6B (Optional System),
Article 6C (Optional Branching Unit), Article 6D (Xxxx'x Crossing), and Article
6E (Alternate Mexico Configuration; Alternate Mexico Configuration Option), the
System will consist of (a) one fiber pair providing a direct connection from
Grover Beach, California, United States to Fort Xxxxxx, Panama and (b) one fiber
pair providing a connection linking (i) Grover Beach, California, United States,
(ii) Puerto Vallarta, Mexico, (iii) Acapulco, Mexico and (iv) Fort Xxxxxx,
Panama;
WHEREAS, Contractor is in the business of designing, constructing,
installing, supplying, delivering and manufacturing fiber optic submarine cable
systems and is familiar with the general business of the fiber optic submarine
cable system industry;
WHEREAS, Purchaser may elect to extend the System from Fort Xxxxxx,
Panama, through Ambush Range, Panama, to St. Croix, United States Virgin
Islands, by including Xxxx'x Crossing (as hereinafter defined);
WHEREAS, Purchaser seeks to purchase and own the System and wishes to
engage Contractor to perform the Work and Upgrade Work; and
WHEREAS, Contractor is willing to perform the Work and the Upgrade
Work on a turn-key, fixed-price basis in accordance with and subject to the
terms hereof.
NOW THEREFORE, IT HAS BEEN AGREED AS FOLLOWS
ARTICLE 1 PROVISION OF SYSTEM
--------- -------------------
In consideration of the Contract Price and the Upgrade Prices, the
Contractor agrees to undertake the Work and the Upgrade Work and to provide the
Purchaser with the
2
System meeting the System Performance Requirements on or before the Scheduled
System RFS Date and the System Upgrades meeting the requirements of Article 6A,
all in accordance with the terms hereof.
ARTICLE 2 DOCUMENTS FORMING THE ENTIRE CONTRACT
--------- -------------------------------------
This Contract consists of these commercial terms and conditions
("Terms and Conditions"), Exhibits E (Approved Subcontractors) and F
(Intellectual Property) hereto, and the following documents (in the form of
attachments, including appendices, attached hereto), which shall be read and
construed as part of the Contract:
. Provisioning Schedule, Appendix 1, Upgrade Provisioning Schedule,
Appendix 1A
. Billing Schedule, Appendix 2, Upgrade Billing Schedule, Appendix 2A
. Plan of Work, Appendix 3, Upgrade Plan of Work, Appendix 3A
. Invoice Format, Appendix 4, Form of Contractor's Certificate,
Appendix 4A
. Progress Schedule, Appendix 5
. Technical Volume (includes Route Information), Appendix 6
. Xxxx'x Crossing Appendix, Appendix 7
In the event of any inconsistency between the Terms and Conditions and
the above listed documents, the Terms and Conditions shall prevail. The
Appendices listed above have no order of precedence.
ARTICLE 3 DEFINITIONS
--------- -----------
Definitions are as described in the specific Articles. Except as
otherwise defined the following definitions shall apply throughout the Contract:
AAA has the meaning set forth in Sub-Article 33(B).
ACCEPTANCE TESTING means (i) with respect to a DLS or the System
(which shall include testing of the Point to Point Pairs), the tests
described in the Commissioning and Acceptance section of the Technical
Volume or developed pursuant to such section by mutual agreement of the
Parties (with 15 days prior notice to the Independent Engineer) and
reasonably designed to verify that such DLS or the System meets the
applicable Performance Requirements and (ii) with respect to any System
Upgrade, the tests described in the Commissioning and Acceptance section of
the Technical Volume or developed pursuant to such section by mutual
agreement of the Parties (with 15 days notice to the Independent Engineer)
and reasonably designed to verify that the System Upgrade meets the
applicable Performance Requirements.
ACCESS RIGHTS means all ownership, easement and/or other property
rights, from both private and governmental entities, both on land and below
the surface of the water (including, without limitation, agreements to use
conduits, install manholes and to lease
3
space in cable stations) necessary to access, use and occupy cable stations
and the sites for cable stations (including, without limitation, to land
and install the submarine cable and related equipment and to bring such
cable from the ocean to the cable stations) in order for the Purchaser to
own, operate and maintain the System.
ACTUAL KNOWLEDGE means the actual knowledge of any executives with
management responsibility for the Contract.
ALTERNATE MEXICO CONFIGURATION means the Base System, reconfigured to
land a two fiber pair cable in each of Tijuana, Mexico and Mazatlan,
Mexico, instead of Puerto Vallarta, Mexico and Acapulco, Mexico,
respectively.
ALTERNATE MEXICO CONFIGURATION OPTION means the Alternate Mexico
Configuration, modified such that an additional fiber pair shall be added
to DLS 1 and DLS 2 making such DLSs upgradeable to 160 Gb/s of capacity at
the Date of Provisional Acceptance.
ASSIGNMENT has the meaning set forth in Sub-Article 37(A).
BANKRUPTCY EVENT means an event specified in Sub-Article 13(A)(3) or
13(A)(4) with Contractor as the "other Party".
BASE SYSTEM means the two fiber pair submarine cable system, including
the cable stations, described in the second WHEREAS clause hereof,
consisting of DLS 1, 2, 3 and 4 (at a per fiber pair capacity of * at
the Date of Commercial Acceptance or the Date of Provisional Acceptance, as
the case may be, of the System, with each DLS having the capability of
being upgraded to * per fiber pair at the Date of Provisional
Acceptance), as more fully described in the System Description section of
the Technical Volume.
BILLING SCHEDULE means, with respect to the System, exclusive of
Xxxx'x Crossing and related options, a billing schedule attached hereto as
Appendix 2 and, with respect to Xxxx'x Crossing and related options, the
billing schedule attached hereto as Appendix 7-2.
CERTIFICATE OF COMMERCIAL ACCEPTANCE means a certificate issued by
Purchaser in accordance with Sub-Article 9(D) to Contractor certifying that
a DLS, the System or a System Upgrade is Ready for Commercial Acceptance.
CERTIFICATE OF FINAL ACCEPTANCE means a certificate issued by
Purchaser in accordance with Sub-Article 9(E) to Contractor certifying that
the System or a System Upgrade is Ready for Final Acceptance.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
4
CERTIFICATE OF PROVISIONAL ACCEPTANCE means a certificate issued by
Purchaser in accordance with Sub-Article 9(C) to Contractor certifying that
a DLS, the System or a System Upgrade is Ready for Provisional Acceptance.
CIF means cost, insurance and freight as defined in the International
Chamber of Commerce, Guide to Incoterms (1990).
COMMISSIONING REPORT has the meaning set forth in the Commissioning
and Acceptance section of the Technical Volume.
CONFIDENTIAL INFORMATION has the meaning set forth in Sub-Article
36(B).
CONSENT means a Consent and Agreement to be entered into among
Contractor, Purchaser and the financing parties described in Sub-Article
37(C) and substantially in the form of Exhibit B hereto, with such changes
therein as made pursuant to Sub-Article 37(C) hereto.
CONTRACT means this agreement, specifically consisting of the
documents described in Article 2, and shall be deemed to include any
amendments thereto or Contract Variations pursuant to Article 6 (Contract
Variations).
CONTRACTOR means the entity that has executed this Contract as
Contractor (TSSL) and that will be responsible for the performance of the
Work (and if applicable, Upgrade Work) under this Contract and shall
include its permitted successors and/or assigns.
CONTRACT PRICE means the Initial Contract Price, plus any variations
pursuant to Article 6 (Contract Variations), Article 6B (Optional System),
Article 6C (Optional Branching Unit), Article 6D (Xxxx'x Crossing), Taxes
as set forth in Sub-Article 4(B) and other adjustments to the Contract
Price provided for in this Contract.
CONTRACT TAXES has the meaning set forth in Sub-Article 4(B)(1).
CONTRACT VARIATION has the meaning set forth in Sub-Article 6(A).
XXXX'X CROSSING shall mean two diverse one fiber pair cables linking
Fort Xxxxxx, Panama to a cable station in Ambush Range, Panama then linked
by a two fiber pair submarine cable to St. Croix (at a per fiber pair
capacity of 10 Gb/s at the Date of Commercial Acceptance or the Date of
Provisional Acceptance, as the case may be, of the System, having the
capability of being upgraded to 160 Gb/s per fiber pair at the Date of
Provisional Acceptance), as more specifically described in Appendix 7
(wherein Xxxx'x Crossing is referred to as the "Optional Extension") and
the Technical Volume.
XXXX'X CROSSING-OPTION has the meaning set forth in Article 6D.
XXXX'X CROSSING OPTION PRICE has the meaning set forth in Article 6D.
5
XXXX'X CROSSING BRANCHING UNIT shall mean a branching unit with a
cable stub attached to Xxxx'x Crossing off the coast of South America or an
island in the Caribbean Sea, which would allow the System to be connected
to an additional cable station to be located in South America or an island
in the Caribbean Sea, as more specifically described in Appendix 7 and the
Technical Volume.
XXXX'X CROSSING BRANCHING UNIT PRICE has the meaning set forth in
Article 6D.
XXXX'X CROSSING DLS means the STM-1 to STM-1 connectivity between Fort
Xxxxxx, Panama and St. Croix.
XXXX'X CROSSING PRICE has the meaning set forth in Article 6D.
DATE OF COMMERCIAL ACCEPTANCE, PROVISIONAL ACCEPTANCE OR FINAL
ACCEPTANCE means the date that Purchaser receives a Commissioning Report or
an Upgrade Commissioning Report, as the case may be, demonstrating that a
DLS or the System or a System Upgrade, as the case may be, is Ready for
Commercial Acceptance, Ready for Provisional Acceptance or Ready for Final
Acceptance in accordance with Article 9 (Acceptance).
DDP means delivered duty paid as defined in the International Chamber
of Commerce, Guide to Incoterms (1990).
DEFAULT means an Event of Default or any event, condition or
occurrence which with the giving of notice or passage of time or both would
be an Event of Default.
DELIVERABLE SOFTWARE has the meaning set forth in Sub-Article 18(C).
DELIVERABLE TECHNICAL MATERIAL has the meaning set forth in Sub-
Article 18(B).
DISPUTE ACCOUNT means the Dispute Account to be created under the
Escrow Agreement.
DLS means a Digital Line Section and includes DLS 1, DLS 2, DLS 3, DLS
4 or the Xxxx'x Crossing DLS, as the case may be.
DLS 1 means the STM-1 to STM-1 connectivity of the System between
Grover Beach, California, United States and Puerto Vallarta, Mexico, as
such DLS may be modified by Article 6E (Alternate Mexico Configuration;
Alternate Mexico Configuration Option).
DLS 2 means the STM-1 to STM-1 connectivity of the System between
Puerto Vallarta, Mexico to Acapulco, Mexico, as such DLS may be modified by
Article 6E (Alternate Mexico Configuration; Alternate Mexico Configuration
Option).
6
DLS 3 means the STM-1 to STM-1 connectivity of the System between
Acapulco, Mexico to Fort Xxxxxx, Panama, as such DLS may be modified by
Article 6E (Alternate Mexico Configuration; Alternate Mexico Configuration
Option).
DLS 4 means the STM-1 to STM-1 connectivity of the System between Fort
Xxxxxx, Panama, to Grover Beach, California, United States.
ESCROW AGENT means The Chase Manhattan Bank, N.A., in its capacity as
escrow agent under the Escrow Agreement, and its successors in such
capacity.
ESCROW AGREEMENT means that Escrow Agreement to be entered into, in
the event of a dispute as described in Sub-Article 5(C)(5), by and among
the Contractor, the Purchaser and the Escrow Agent, substantially in the
form of Exhibit D hereto, with such changes therein as are reasonably
requested by the Escrow Agent, as amended modified or supplemented from
time to time.
EVENT OF DEFAULT has the meaning set forth in Sub-Article 13(A).
EXCLUDED TAX means (i) any franchise, excess profits, net worth,
capital or capital gains Tax, as well as any Tax on doing business or
imposed on net or gross income or receipts (including minimum and
alternative minimum Taxes measured by any items of Tax preference), but in
each case excluding Taxes that are or are in the nature of sales, use,
excise, license, stamp, rental, ad valorem, value added or property Taxes;
(ii) any Taxes imposed by a jurisdiction other than one in which (a) the
Contractor is or is treated as engaged in activities contemplated by or in
fulfillment of the Contract or (b) the Purchaser or its affiliates has a
nexus to such jurisdiction and the Tax imposed is attributable to that
nexus, (iii) Taxes imposed on the Contractor as a result of Contractor's
gross negligence or willful misconduct and (iv) any import duty, other
import related charges, sales or use tax, VAT or property tax imposed by
the United States or any political subdivision thereof or Taxing authority
therein in respect of Supplies brought into the United States for testing,
modification or other similar purposes prior to being installed or used
outside the United States.
EXPEDITED UPGRADE has the meaning set forth in Sub-Article 6A(L).
FINAL COMMISSIONING REPORT has the meaning set forth in Section 7,
Commissioning and Acceptance section of the Technical Volume.
FINAL SURVEY REPORT means the final survey report described in Section
5 of the Marine Installation section of the Technical Volume.
FOB means free on board as defined in the International Chamber of
Commerce, Guide to Incoterms (1990).
FORCE MAJEURE has the meaning set forth in Sub-Article 17(A).
7
*
*
INDEPENDENT ENGINEER means Conexart Technologies, Inc. or a similarly
qualified successor in the capacity as the engineer to the financing
sources specified in Sub-Article 37(C) who has agreed to be bound by the
confidentiality provisions of this Contract and who is not affiliated with
a competitor of Contractor.
INFORMATION has the meaning set forth in Sub-Article 20(A).
INITIAL CONTRACT PRICE has the meaning set forth in Sub-Article
4(A)(1).
INITIAL UPGRADE PRICE has the meaning set forth in Sub-Article
4(A)(2).
INTELLECTUAL PROPERTY has the meaning set forth in Sub-Article 18(A).
LANDING LICENSES means, in the United States (including St. Croix), a
License to land and operate a Submarine Cable System pursuant to the
Submarine Cable Landing Act, 47 U.S.C. 34-39 and, in Mexico and Panama, the
comparable license which is required under Mexican and Panamanian law,
respectively.
LAWS means any laws, ordinances, regulations, rules, orders,
proclamations, requirements of governmental authorities or treaties.
MANUFACTURING MATERIALS has the meaning set forth in Sub-Article
13(B).
MILESTONES means, with respect to the System, exclusive of Xxxx'x
Crossing and related options, the milestones set forth in the Progress
Schedule attached as Appendix 5 hereto and, with respect to Xxxx'x Crossing
and related options, the milestones set forth in the Progress Schedule
attached as Appendix 7-4 hereto.
NEXUS TAX means any Tax imposed by way of withholding in respect of or
in lieu of an Excluded Tax, but only to the extent such Tax would not have
been imposed but for the nexus (other than as a consequence of the
activities of the Contractor) of the Purchaser or its affiliate to the
jurisdiction imposing the Tax.
NON-SHIP COSTS has the meaning set forth in Sub-Article 10(A)(2).
NOTICE OF TERMINATION has the meaning set forth in Sub-Article 14(A).
OPTIONAL BRANCHING UNIT shall mean a branching unit with a cable stub
attached to the System off the coast of Central America, which would allow
the System to be
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
8
connected to a cable station to be located in Central America or the
northwest coast of South America, as more specifically described in Section
1.8 of the Technical Volume.
OPTIONAL BRANCHING UNIT PRICE has the meaning set forth in Article 6C.
OPTIONAL SYSTEM means the * additional fiber pairs placed in the
same cables as the initial fiber pairs of the Base System; provided, that
--------
there will be no additional terminal station equipment for the additional
* fiber pairs (which will not initially be equipped with terminal station
equipment) all of which is more particularly described in Section 1.8 of
the Technical Volume.
OPTIONAL SYSTEM PRICE has the meaning set forth in Sub-Article 6B.
PARTY(IES) means either of the Purchaser and/or the Contractor, as
appropriate.
PERFORMANCE REQUIREMENTS means (i) with respect to a DLS or the
System, the applicable System Performance Requirements set forth or to be
developed by mutual agreement pursuant to the System Performance and
Availability section of the Technical Volume, (ii) with respect to any
System Upgrade, the applicable System Performance Requirements set forth in
or to be developed by mutual agreement pursuant to the Technical Volume or
(iii) in each case, such other DLS, System or System Upgrade performance
levels as mutually agreed by the Parties.
PERMITS means all Access Rights, permits, pipeline and cable crossing
agreements, approvals, "no objections", permissions-in-principle,
authorizations, consents, customs clearances, registrations, certificates,
rights-of-way, certificates of occupancy, licenses, including without
limitation, landing licenses, orders, vessel and crew authorizations/visas,
permission for the operation of navigational aids and radio systems and
similar authorizations necessary to complete the Work and operate and
maintain the System (other than any of the foregoing (i) relating to the
ownership, operation and maintenance of the System and not necessary until
after the System is Ready for Final Acceptance, (ii) which is or would be
needed by Purchaser to engage in any business outside the business of
developing, owning and operating a submarine cable system, (iii) which is
or would be needed at any time by any purchaser or lessee of capacity on
the System, or (iv) the Landing Licenses provided for in Sub-Article 7(C)).
POINT TO POINT PAIRS means the STM-1 to STM-1 connectivity between any
one cable station to any other cable station in the System.
PROVISIONING SCHEDULE means, with respect to the System, exclusive of
Xxxx'x Crossing and related options, the price schedule attached hereto in
Appendix 1 and, with respect to Xxxx'x Crossing and related options, the
price schedule attached hereto in Appendix 7-1.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
9
PURCHASER means Pan American Crossing Ltd. and shall include its
permitted successors and assigns.
READY FOR COMMERCIAL ACCEPTANCE means
(i) for any DLS, that
(a) if the System is not at the same time also Ready for
Commercial Acceptance, the Purchaser has consented, in its sole
discretion, to accept such DLS as Ready for Commercial
Acceptance,
(b) such DLS has the ability to carry commercial traffic
between the two landing points of such DLS meeting performance
criteria equal to twice that of ITU-T G.826 as defined in the
System Performance section of the Technical Volume and has line
monitoring and protection switching capability,
(c) Contractor has tested and provided for STM-1
interconnectivity capability (or such other interconnectivity
capability as may be mutually agreed) to the DLS terminal
equipment according to XXX-X X.000,
(x) Contractor has substantially performed its obligations
under Article 18 (Intellectual Property) then required to be
performed by it, and
(e) all Permits are obtained for such DLS, and
(ii) for the System,
(a) that the System has the ability to carry commercial
traffic throughout the System, and for each Point to Point Pair,
(operating at 10 Gb/s per fiber pair) meeting performance
criteria equal to twice that of ITU-T G.826 as defined in the
System Performance section of the Technical Volume with self
healing ring protection capability and per DLS protection
capability, has line monitoring and per DLS protection switching
capability and has network management capability (all as
described in the System Description section of the Technical
Volume and in Appendix 7),
(b) Contractor has tested and provided for STM-1
interconnectivity capability (or such other interconnectivity
capability as may be mutually agreed) to the System terminal
equipment according to ITU-T G.826,
10
(c) Contractor has substantially performed its obligations
under Article 18 (Intellectual Property) then required to be
performed by it and
(d) all Permits are obtained for the System and
(iii) for any System Upgrade, the System is Ready for Commercial
Acceptance at the capacity specified for such System Upgrade.
READY FOR FINAL ACCEPTANCE means
(i) for the System, that
(a) (I) the System has successfully and continuously
(other than by reason of Force Majeure in which case the test
period shall be extended for a time period equal to the time
period of such Force Majeure) functioned in compliance with the
System Performance Requirements during the period of ninety (90)
consecutive days after the Date of Provisional Acceptance or
(II) if the System shall have failed to meet the System
Performance Requirements at any time during such period (other
than by reason of Force Majeure), the Contractor has corrected
such failure and the System has successfully and continuously
(other than by reason of Force Majeure in which case the test
period shall be extended for a time period equal to the time
period of such Force Majeure) functioned in compliance with the
System Performance Requirements for such additional period of
time not to exceed ninety (90) days (and not to end prior to the
date 90 days after the Date of Provisional Acceptance) as
reasonably determined by the Independent Engineer as being
sufficient to confirm that such failure has been corrected and
that no other failures are likely to appear and
(b) all deficiencies noted in the Certificate of Provisional
Acceptance have been corrected (other than minor deficiencies
which will not affect the operation of the System, in respect of
which an equitable adjustment to the Contract Price will be made)
and
(c) Contractor has complied in all material respects with
Article 18 (Intellectual Property) and
(ii) for any System Upgrade, that
(a) (I) the System Upgrade has successfully functioned in
compliance with the System Performance Requirements during the
period of ninety (90) days after the Date of Provisional
Acceptance of the System
11
Upgrade or (II) if the System Upgrade shall have failed to meet
the System Performance Requirements during such period, the
Contractor has corrected such failure and the System Upgrade has
successfully functioned in compliance with the System Performance
Requirements for such additional period of time not to exceed
ninety (90) days as reasonably determined by the Independent
Engineer as sufficient to confirm that such failure has been
corrected and
(b) all deficiencies noted in the Certificate of Provisional
Acceptance have been corrected (other than minor deficiencies
which will not affect the operation of the System, in respect of
which an equitable adjustment of the Contract Price will be made)
and
(c) Contractor has complied in all material respects with
Article 18 (Intellectual Property).
READY FOR PROVISIONAL ACCEPTANCE means
(i) with respect to any DLS,
(a) in the case of all DLSs, if the System is not, at the
same time, also Ready for Provisional Acceptance, the Purchaser
has consented, in its sole discretion, to accept such DLS as
Ready for Provisional Acceptance,
(b) such DLS is complete in all material respects (and in
any event is Ready for Commercial Acceptance),
(c) the results of Acceptance Testing of such DLS
demonstrate that such DLS has satisfied the System Performance
Requirements,
(d) Contractor has substantially performed its obligations
under Article 18 (Intellectual Property) then required to be
performed by it,
(e) all Permits are obtained for such DLS, and
(ii) with respect to the System, the System is complete in all
material respects (and in any event is Ready for Commercial
Acceptance), all DLSs are Ready for Provisional Acceptance with self-
healing ring protection capability and per DLS protection capability
and line monitoring and network management capability (all as
described in the System Description section of the Technical Volume
and Appendix 7) and
(iii) with respect to any System Upgrade, the results of
Acceptance Testing of such System Upgrade demonstrate that such System
Upgrade is
12
complete in all material respects and is sufficient to realize the
Performance Requirements.
REPRESENTATIVES has the meaning set forth in Article 36(B).
RETAINAGE means an amount equal to * of the Initial Contract Price.
RETESTING has the meaning set forth in Sub-Article 9(B)(3).
ROUTE SURVEY means the route survey described in the Marine section of
the Technical Volume.
SCHEDULED SYSTEM RFS DATE has the meaning set forth in Sub-Article
9(A).
SCHEDULED UPGRADE DATE means for any System Upgrade, the date by which
the Contractor agrees such System Upgrade will be Ready for Provisional
Acceptance pursuant to Sub-Article 6A(K) hereof.
SEGMENT means Segment 1, Segment 2, Segment 3, Segment 4 or Segment 5,
as the case may be.
SEGMENT 1 means the Segment of the System from Grover Beach,
California, United States to Branching Unit 1 and landing in Xxxxxx Beach
in locations capable of interconnecting with major telecommunications
carriers.
SEGMENT 2 means the Segment of the System from Branching Xxxx 0 xx
Xxxxxx Xxxxxxxx, Xxxxxx and landing in Puerto Vallarta in locations capable
of interconnecting with major telecommunications carriers, as such Segment
may be modified by Article 6E (Alternate Mexico Configuration; Alternate
Mexico Configuration Option).
SEGMENT 3 means the Segment of the System from Branching Unit 1 to
Branching Unit 2.
SEGMENT 4 means the Segment of the System from Branching Unit 2 to
Acapulco, Mexico and landing in Acapulco in locations capable of
interconnecting with major telecommunications carriers, as such Segment may
be modified by Article 6E (Alternate Mexico Configuration; Alternate Mexico
Configuration Option).
SEGMENT 5 means the Segment of the System from Branching Unit 2 to
Fort Xxxxxx, Panama and landing in Fort Xxxxxx in locations capable of
interconnecting with major telecommunications carriers.
SHIP COSTS has the meaning set forth in Sub-Article 10(A)(2).
SHIP PERIOD has the meaning set forth in Sub-Article 10(A).
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
13
SUPPLIES means any and all materials, plant, machinery, equipment,
hardware and items supplied by the Contractor under this Contract.
SUSPENSION means a suspension in Work pursuant to Sub-Article 15(A) or
15(B).
SYSTEM means the Base System; provided, that the term "System" shall
for all purposes of this Contract, including without limitation, Sub-
Article 9(A)(7) and Article 22, include each option listed in Articles 6B
through 6D, to the extent elected by Purchaser, except to the extent
expressly herein stated otherwise.
SYSTEM PERFORMANCE REQUIREMENTS has the meaning set forth in the
System Description section of the Technical Volume.
SYSTEM UPGRADE has the meaning set forth in Sub-Article 6A(A).
TAX means any tax, duty, levy, charge or custom (including, without
limitation, any sales or use tax, VAT or octroi duty relating to the
Contract items and fiscal stamps connected with Contract legalization)
imposed or collected by any taxing authority or agency (domestic or
foreign).
TECHNICAL VOLUME means, with respect to the System, the Technical
Volume attached hereto as Appendix 6 and, with respect to Xxxx'x Crossing
and related options, includes Appendix 7-5.
TRANSFEREE means any entity to which purchaser assigns rights
hereunder pursuant to Sub-Article 37(D) hereof.
UPGRADE BILLING SCHEDULE means, with respect to the System, exclusive
of Xxxx'x Crossing and related options, the billing schedule attached
hereto as Appendix 2A and, with respect to Xxxx'x Crossing and related
options, the billing schedule attached hereto as Appendix 7-2A.
UPGRADE COMMISSIONING REPORT has the meaning set forth in the
Commissioning and Acceptance section of the Technical Volume.
UPGRADE OPTION PERIOD has the meaning set forth in Sub-Article 6A(B).
UPGRADE PLAN OF WORK means, with respect to the System, exclusive of
Xxxx'x Crossing and related options, the plan of work attached hereto as
Appendix 3A and, with respect to Xxxx'x Crossing and related options, the
plan of work attached hereto as Appendix 7-3A.
UPGRADE PRICE means, for any System Upgrade, the Initial Upgrade Price
for such System Upgrade, plus any variations pursuant to Article 6
(Contract Variations),
14
Taxes as set forth in Sub-Article 4(B) and other adjustments to such
Upgrade Price provided for in this Contract.
UPGRADE PROVISIONING SCHEDULE means, with respect to the System,
exclusive of Xxxx'x Crossing and related options, the provisioning schedule
attached hereto as Appendix 1A and, with respect to Xxxx'x Crossing and
related options, the provisioning schedule attached hereto as Appendix 7-
1A.
UPGRADE WARRANTY PERIOD has the meaning set forth in Sub-Article
10(A).
UPGRADE WORK means the activities and services to be performed or
provided by Contractor under Article 6A (Optional Upgrades).
*
WARRANTY PERIOD has the meaning set forth in Sub-Article 10(A).
WORK means all activities and services (other than the activities and
services specified in this Contract to be provided by Purchaser) necessary
to be performed or provided in developing, planning, designing,
manufacturing, constructing, delivering, installing and testing the System,
until the System is Ready for Final Acceptance, including without
limitation, designating, coordinating, obtaining and paying for on behalf
of Purchaser the Access Rights and obtaining all Permits except Landing
Licenses. Whether or not used in conjunction with the term "Supplies", the
term "Work" shall always be deemed to include the provision of the relevant
Supplies, unless the context requires otherwise.
YEAR 2000 COMPLIANT means, when used with respect to any software or
materials, that such software or materials will operate accurately and,
without
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
15
interruption, accept, possess and in all manner retain full functionality
when referring to, or involving, any year or date in the twentieth or
twenty-first centuries.
ARTICLE 4 CONTRACT PRICE
--------- --------------
A. Contract Price
1. The initial Contract Price for the Work, in United States Dollars
(US$) is a fee of * (the "Initial Contract Price"). The Initial
Contract Price does not include the cost of optional upgrades
which are described in Article 6A (Optional Upgrades), any
contract variations as provided for in Article 6 (Contract
Variations), Article 6B (Optional System), Article 6C (Optional
Branching Unit), Article 6D (Xxxx'x Crossing), or any Taxes. The
Initial Contract Price includes, with respect to the Base System,
all charges for CIF, and all costs and expenses incurred in
obtaining all Permits (including Access Rights) and includes all
the Work.
2. The Initial Upgrade Price for any Upgrade Work, in United States
Dollars (US$) is the fixed fee set forth in (with respect to the
System, exclusive of Xxxx'x Crossing and related options),
Appendix 2A and (with respect to Xxxx'x Crossing and related
options), Appendix 7-2A (the "Initial Upgrade Price"). No Initial
Upgrade Price includes the cost of any contract variations as
provided for in Article 6 (Contract Variations) or any Taxes.
3. The Provisioning Schedule sets forth the Contractor's estimate of
the breakdown of the Initial Contract Price among various aspects
of the Work. If the actual cost of any aspect of the Work is
greater or less than that set forth in the Provisioning Schedule,
such fact shall not cause any change in the Initial Contract
Price, except as set forth in Sub-Article 6(D).
4. Without the prior written consent of the Purchaser, which consent
shall not be unreasonably withheld or delayed, the Contractor
shall not arrange for any
(a) Access Right which requires payments to be made by the
Purchaser or made after the System is Ready for Provisional
Acceptance or
(b) Permit which requires aggregate payments in excess of
* to be made by Purchaser or made after the System
is Ready for Provisional Acceptance.
B. Taxes, Levies and Duties
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
16
1. The Initial Contract Price and each Initial Upgrade Price, as
stated in Sub-Article 4(A) above, excludes any Tax. The Contract
Price and each Upgrade Price shall without duplication be
adjusted for any Tax imposed on or in connection with this
Contract (including, without limitation, the execution and
delivery of this Contract, the Work, the Upgrade Work and the
Supplies, but excluding any Excluded Taxes) (any such Taxes,
other than Excluded Taxes, are hereinafter referred to as
"Contract Taxes"). Contractor has provided a good faith estimate
of the Contract Taxes payable by the Purchaser; it being
understood that the Contractor shall have no liability under this
Contract or otherwise to the Purchaser for any errors or
omissions in such estimate or any losses arising therefrom. The
Contractor shall be responsible for any Excluded Tax that might
be incurred by the Contractor as well as any Tax described in
clause (iv) of the definition of Excluded Tax.
2. The Purchaser will be ultimately responsible for the payment of
all Contract Taxes (including, without limitation, Contract Taxes
that are VAT, octroi duties relating to Contract items and fiscal
stamps, etc. connected with Contract legalizations to the
authorities in their countries). In the case of any Contract
Taxes paid by the Contractor, the Contractor shall submit payment
on the Purchaser's behalf and Contractor will be reimbursed by
the Purchaser in accordance with Article 5 (Terms of Payment by
Purchaser).
3. The Contractor agrees to use reasonable efforts including,
without limitation, by registering for VAT and any applicable
sales Taxes in any country, state or other jurisdiction where
legally required, to cooperate with and assist Purchaser in its
efforts (i) to have Supplies which are the subject of this
Contract made exempt from Contract Taxes, whether in the
manufacture of the Supplies or related to the importation or
location or installation of the Supplies, (ii) to request
revisions, drawbacks, remissions, reclassifications or the like
to the jurisdictions identified by the Purchaser; or (iii) to
reduce or eliminate Contract Taxes (including the provision of
applicable certifications and forms) and to obtain any available
refunds of Contract Taxes, provided that the Contractor shall not
--------
be required to act other than in accordance with the relevant
Laws then in force. The Purchaser shall reimburse the Contractor,
in accordance with Article 5, for any reasonable costs (including
the reasonable fees and expenses of legal counsel, accountants
and other advisors) incurred by the Contractor under this Sub-
Article 4(B)(3) provided that Purchaser was notified and has
--------
consented to the incurrence of such costs, fees and expenses.
Contractor shall not be required to cooperate with and assist
Purchaser in its efforts under this Sub-Article 4(B)(3) or to
take any action hereunder which in the Contractor's good faith
judgment would incur any costs or if in Contractor's good faith
judgment it would be advisable to obtain the advice of counsel,
accountants or other advisors prior to
17
cooperating with or assisting purchaser or taking any action,
unless in each case, Purchaser has agreed to reimburse Contractor
under the foregoing proviso.
4. Prior to the Date of Provisional Acceptance with respect to the
System or any System Upgrade, the Contractor shall provide
evidence of having made all payments for Taxes included in the
Contract Price or Upgrade Price or described in clause (iv) of
the definition of Excluded Taxes, other than VAT due on payments
of the Contract Price or Upgrade Price made on or after the Date
of Provisional Acceptance of the System or System Upgrade, which
evidence shall be provided within sixty (60) days of the date of
each such payment.
5. As part of Work or any Upgrade Work, the Contractor shall obtain
at its expense, on Purchaser's behalf, any import license or
other official authorization and carry out all customs
formalities necessary for the importation or exportation of goods
in connection with such Work or Upgrade Work. The Purchaser
agrees to be the Importer or Exporter of Record or designate an
Importer or Exporter of Record/Consignee on its behalf. Purchaser
must provide a Letter of Authorization from any third party
designate stating it agrees to be the Importer or Exporter of
Record on Purchaser's behalf and identify the name and address of
the designated Importer or Exporter of Record.
6. The Supplies to be installed or held on land shall be delivered
to the agreed point at the named place of destination and shall
be consigned to the Purchaser.
C. Withholding Tax
1. If withholding for any Tax is required in respect of any payment
to the Contractor, the Purchaser shall (i) withhold the
appropriate amount from such payment, (ii) pay such amount to the
relevant authorities in accordance with the applicable Laws and
(iii) in the case of any such withholding in respect of a
Contract Tax or a Nexus Tax and subject to the Contractor's
satisfying the obligations set forth in the last sentence of this
Sub-Article 4(C)(1), pay the Contractor an additional amount such
that the net amount received by the Contractor is the amount the
Contractor would have received in the absence of such
withholding. In such a case, the Purchaser shall provide to the
Contractor, as soon as reasonably practicable, a certified copy
of an official tax receipt for any Tax which is retained from any
payment due to the Contractor or for any Tax which is paid on
behalf of the Contractor. All such receipts shall be in the name
of the Contractor. The Contractor agrees to complete accurately
and timely provide to the Purchaser or, if required, to the
applicable taxing authority, such forms, certifications or other
documents as may be requested in
18
timely manner by Purchaser, in order to allow it to make payments
to the Contractor without any deduction or withholding on account
of withholding Taxes (or at a reduced rate thereof) or to receive
a refund of any amounts deducted or withheld on account of
withholding Taxes.
2. If the Contractor shall become aware that it is entitled to
receive a refund or credit from a relevant taxing or governmental
authority in respect of a Contract Tax or Nexus Tax as to which
the Purchaser has paid an additional amount pursuant to Sub-
Article 4(C)(1) above, the Contractor shall promptly notify the
Purchaser of the availability of such refund or credit and shall,
within 30 days after receipt of a request by the Purchaser
(whether as a result of notification that it has made to the
Purchaser or otherwise), make a claim to such taxing or
governmental authority for such refund or credit at the
Purchaser's expense. If the Contractor receives a refund or
credit in respect of a Contract or Nexus Tax as to which the
Purchaser has paid an additional amount pursuant to Sub-Article
4(C)(1) above, or if, as a result of the Purchaser's payment of
such additional amounts, the Contractor or any other member of an
affiliated group, as defined in section 1504(a) of the Code, of
which the Contractor is a member, receives a credit against Taxes
imposed on its income or franchise taxes imposed on it by the
country under the laws of which it is organized or any political
subdivision thereof, the Contractor shall promptly notify the
Purchaser of such refund or credit and shall within 30 days from
the date of receipt of such refund or benefit of such credit pay
over the amount of such refund or benefit of such credit
(including any interest paid or credited by the relevant taxing
or governmental authority with respect to such refund or credit)
to the Purchaser (but only to the extent of the additional
payments made by the Purchaser under Sub-Article 4(C)(1) above
with respect to the Contract or Nexus Tax giving rise to such
refund or credit), net of all out-of-pocket expenses of the
Contractor; provided, however, that the Purchaser, upon the
-------- -------
request of the Contractor, agrees to repay the amount paid over
to the Purchaser (plus penalties, interest or other charges due
to the appropriate authorities in connection therewith) to the
Contractor in the event the Contractor is required to repay such
refund or credit to such relevant authority.
ARTICLE 5 TERMS OF PAYMENT BY PURCHASER
--------- -----------------------------
A. General Conditions of Payment
1. All payments shall be made and all invoices shall be rendered in
US Dollars (US$). The Purchaser shall be responsible for and
shall pay all costs and fees for payment, as well as the banking
and wiring costs. All banking documents and correspondence must
be in English.
19
B. Invoice Procedures
1. All invoices for Work shall be submitted according to the Billing
Schedule, provided, that at the time of any such Invoice the
--------
relevant Milestones have been achieved. All invoices for Work
shall have a certificate addressed to Purchaser in the form of
Appendix 4A attached.
2. Any Contract Variations shall be invoiced and paid in accordance
with the terms of the Contract Variation as specified in Article
6 (Contract Variations).
3. Invoices for Upgrade Work shall be submitted according to the
Upgrade Billing Schedule and shall be paid in accordance with
this Article 5.
4. Invoices for amounts not described in Sub-Sections 1-3 above,
which may become payable hereunder shall be submitted after
applicable costs have been incurred or such other time as may be
specified in this Contract. Such invoices shall be accompanied by
a certificate of the Contractor explaining such amount and
certifying that it is payable.
5. The Contractor shall render all invoices to the following address
or facsimile number:
Pan American Crossing Ltd.
Wessex House
00 Xxxx Xxxxxx
Xxxxxxxx XX00
Xxxxxxx
Xxxxxxxxx: 000-000-0000/8606
Attn: Xxxxxx Xxxx
with a copy to
Conexart Technologies, Inc.
000 xx Xxxxxxxx
Xxxxx Xxxxxxx
Xxxxxx, Xxxxxx
X0X 0X0
Facsimile: 000-000-0000
Attn: Xx. Xxxxxx Xxxxxxxx
C. Payment Procedures
1. The Purchaser shall pay the Contractor, and the Contractor shall
accept payment, in accordance with this Article 5 (Terms of
Payment by Purchaser).
20
2. Purchaser agrees to pay an initial payment to Contractor in the
amount of *. Within three business days of the time this Contract
is executed and delivered by both Parties, the first portion of
the initial payment, in the amount of *, shall be paid by
Purchaser to Contractor. The second portion of the initial
payment, in the amount of *, shall be paid by Purchaser to
Contractor within 56 days of the execution and delivery of this
Contract by both Parties. Failure to receive these payments shall
entitle Contractor, upon 2 business days' notice to Purchaser of
intent to suspend, to immediately suspend Work hereunder and, in
the case of such suspension, to an equitable extension in the
Scheduled System RFS Date.
2a. In the event the Optional System is elected, Purchaser agrees to
pay an initial payment to Contractor in the amount of * of the
Optional System Price. Within three business days after such
election, the first portion of such initial payment, in the
amount of * of the Optional System Price, shall be paid by
Purchaser to Contractor. The second portion of such initial
payment, in the amount of * of the Optional System Price, shall
be paid by Purchaser to Contractor within 56 days of the date of
such election. Failure to receive these payments shall entitle
Contractor, upon 2 business days' notice to Purchaser of intent
to suspend, to immediately suspend Work relating to the Optional
System, and, in the case of such suspension, to an equitable
extension in the Scheduled System RFS Date.
2b. In the event Xxxx'x Crossing, and any related options as are set
forth in Article 6D, is elected, Purchaser agrees to pay an
initial payment to Contractor in the amount of *. Within three
business days after such election, the first portion of such
initial payment, in the amount of *, shall be paid by Purchaser
to Contractor. The second portion of such initial payment, in the
amount of *, shall be paid by Purchaser to Contractor within 56
days of the date of such election. Failure to receive these
payments shall entitle Contractor, upon 2 business days' notice
to Purchaser of intent to suspend, to immediately suspend Work
relating to the Xxxx'x Crossing, and, in the case of such
suspension, to an equitable extension in the Scheduled System RFS
Date.
3. Invoices given to the Purchaser (and the Independent Engineer) on
or before the last day of any month shall, subject to Sub-Article
5(C)(5) below, be due and payable on the last day of the next
month or such other time as may be specified in this Contract;
provided that invoices given to Purchaser on or before June 30,
--------
1998 shall be due and payable no earlier than August 31, 1998.
4. Invoices not paid when due shall accrue late payment charges from
the day, following the day, on which payment was due until the
day on which it is paid. Invoices for such extended payment
charges shall not be issued
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
21
for an amount less than U.S. $1,000. Extended payment charges
shall be computed at the rate of one percent (1%) per month.
5. In the event that the Purchaser has an objection to any invoice
or other payment obligation or any amount owing by Contractor to
Purchaser shall not have been paid when due, the Purchaser shall
promptly notify the Contractor of such objection and such amount,
and the Purchaser and Contractor shall make every reasonable
effort to settle promptly the dispute concerning the payment(s)
in question. In the event such dispute cannot be settled, the
Purchaser will have the right to withhold payment of the disputed
amount(s) (or withhold from the invoice amount a sum equal to the
amount purportedly owing by Contractor) so long as it deposits,
in full, such disputed amount(s) into the Dispute Account.
(a) Provided such disputed amount is placed into the Dispute
Account in a timely manner, the Purchaser shall not be
deemed to be in breach of or in default for failing to pay
Contractor.
(b) The Escrow Agent will distribute the disputed amount in
accordance with the terms of the Escrow Agreement.
(c) In addition, the prevailing Party shall be entitled to
receive from the Dispute Account an amount equal to the
interest earned by the Escrow Agent on the distributed,
disputed amount, which shall be distributed by the Escrow
Agent under clause (b) above.
The Contractor and the Purchaser will share equally the costs and
expenses of the Escrow Agent.
The Contractor and the Purchaser will execute and deliver an
Escrow Agreement substantially in the form of Exhibit D hereto,
with such changes therein as the Escrow Agreement may reasonably
request.
6. The Purchaser shall make timely payments for that portion of the
invoice not in dispute in accordance with Sub-Article 5(C) or
such payments will be assessed extended payment charges as set
forth in Sub-Article 5(C)(4). Pending resolution of the dispute,
the Purchaser may not withhold payment (unless also subject to
dispute) on any other invoice concerning different goods and/or
services submitted by Contractor.
ARTICLE 6 CONTRACT VARIATIONS
--------- -------------------
A. Either Party may request, during construction of the System or any
System Upgrade, by written order, a contract variation requiring additions or
alterations to, deviations or deductions from the System or System Upgrade
("Contract Variation"). If the other Party
22
consents, in its sole discretion, this change will be formalized as an amendment
to this Contract by a Contract Variation; provided, that the Contractor will not
--------
unreasonably withhold its consent to a Contract Variation requested by the
Purchaser; and provided further, that Purchaser will not unreasonably withhold
----------------
its consent to a Contract Variation requested by the Contractor so long as such
Contract Variation does not affect the Contract Price, any Upgrade Price, the
Scheduled System RFS Date, any Scheduled Upgrade Date, any warranties or the
Performance Standards.
B. A Contract Variation shall not become effective unless and until the
price adjustment, the terms and schedule of payment and the extension of time
and all other terms have been mutually agreed upon by the Parties (and the
Parties shall act reasonably and in good faith in connection with all such
terms) and such Contract Variation is signed by an authorized representative of
each Party. Each Contract Variation shall be incorporated as an amendment to the
Contract.
C. Contractor may seek a Contract Variation for any change, after the date
of execution and delivery of this Contract by both Parties, of any Law (except,
and to the extent, affecting Taxes or wages) which requires a change in the Work
or the Upgrade Work or affects the costs (other than wages) incurred or to be
incurred by the Contractor or any combination of the foregoing and Purchaser
shall agree to any such change in Work or Upgrade Work as may be required and to
an equitable adjustment to the Contract Price or the applicable Upgrade Price.
As of the date hereof, neither Party has Actual Knowledge of any proposed change
in any Law that would require a change in the Work or the Upgrade Work.
D. The Initial Contract Price is based on the assumptions that (i)
Contractor will acquire ownership of land and build, on such land, two cable
stations in Mexico and one cable station on the Pacific coast of Panama and will
acquire additional land and will enlarge an existing cable station in the United
States and (ii) the beach manhole to cable station distance with respect to the
two cable stations in Mexico will be no more than four (4) miles in total. To
the extent that such assumptions are incorrect (if, for example, the Contractor
or the Purchaser shall lease space in one or more existing cable stations) both
Parties will agree to an equitable adjustment, up or down, to the Contract Price
and the terms and schedule of payments. The Contractor will consult with, and
obtain the consent of the Purchaser (not to be unreasonably withheld or delayed)
regarding the location of cable stations and whether to acquire, build, or lease
such cable stations. Any lease for space in a cable station shall be reasonably
satisfactory in form and substance to the Purchaser. The Initial Contract Price
is also based on the assumption that the SDH low speed interconnect
configuration shall be as set forth in the System Description section of the
Technical Volume. Purchaser may elect to change such configuration by
eliminating, replacing or adding STM-1 optical interfaces, SDH equipment, DS-3s
and/or E1s, each with respect to one or more DLSs. If Purchaser makes such
election, both Parties shall agree to an equitable adjustment, up or down, based
on the prices set forth in the Provisioning Schedule, to the Contract Price
and/or the Scheduled System RFS Date, as necessary. The equitable adjustment
shall take into account the actual costs incurred by Contractor, such as costs
associated with cancelling firm commitments.
ARTICLE 6A. OPTIONAL UPGRADES
----------- -----------------
23
A. This Article includes the terms and conditions governing an option for
future upgrades to the System (each a "System Upgrade") that may be exercised by
Purchaser during the Upgrade Option Period.
B. *
C. *
D. *
E. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
24
F. *
G. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
25
H. *
I. *
J. *
K. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
26
L. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
27
M. *
ARTICLE 6B OPTIONAL SYSTEM
---------- ---------------
A. *
B. *
ARTICLE 6C OPTIONAL BRANCHING UNIT
---------- -----------------------
*
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
28
ARTICLE 6D XXXX'X CROSSING
---------- ---------------
A. *
B. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
29
C. *
ARTICLE 6E ALTERNATE MEXICO CONFIGURATION; ALTERNATE MEXICO CONFIGURATION
---------- --------------------------------------------------------------
OPTION
------
A. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
30
B. *
C. *
D. *
ARTICLE 7 RESPONSIBILITIES FOR PERMITS ; COMPLIANCE WITH LAWS
--------- ---------------------------- ----------------------
A. The Purchaser shall reasonably cooperate with and assist the Contractor to
obtain all Permits, including Access Rights (except those specified in paragraph
C below), to the extent that Purchaser's cooperation and assistance are
necessary for Contractor to expeditiously and cost-efficiently obtain such
Permits. The Purchaser agrees to respond promptly to any such request from
Contractor. Further, the Purchaser agrees that it will not impede or interfere
with Contractor's activities or Contractor's abilities to perform its
obligations. Upon notice from Contractor with respect to a Permit or receipt by
Purchaser of a copy of a Permit, Purchaser shall fulfill all conditions of such
Permit and perform all responsibilities thereunder, except to the extent that
such conditions or responsibilities are those of the Contractor under Work.
Contractor will inform Purchaser as to any such conditions or responsibilities
that, in the Contractor's reasonable judgment, are not ordinary and routine and
obtain Purchaser's consent, which consent shall not be unreasonably withheld,
thereto prior to arranging for any such Permit.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
31
B. Subject to paragraph C below, the Contractor shall have the responsibility
for obtaining, at Contractor's sole cost and expense (subject to Sub-Articles
6D(A) and 6D(B)), all Permits on Purchaser's behalf. The Contractor will cause
all Permits not issued in the name of Purchaser to be assignable to Purchaser,
and to be assigned to Purchaser at the time title to the System is transferred
to Purchaser pursuant to this Contract. Subject to Sub-Article 4(A)(4),
Purchaser shall be responsible for payment of all Permit fees and other costs
and expenses due with respect to any Permit after the Date of Provisional
Acceptance of the System.
C. The Purchaser shall be responsible for obtaining, at its expense, all
Landing Licenses that the System requires (which shall include all Landing
Licenses that Xxxx'x Crossing requires). The Contractor will cooperate with the
Purchaser in connection therewith. Purchaser shall reimburse reasonable outside
counsel fees, reasonable independent consultant fees and other reasonable out-
of-pocket expenses incurred by Contractor in connection with such cooperation.
D. Any delay in obtaining or failure to obtain any Permit shall constitute a
Force Majeure and be treated as described in Article 17 (Force Majeure), except
to the extent such delay is a result of Contractor's negligence or willful
misconduct.
E. Except with respect to variations necessitated by complying with any
changes, enacted after the date hereof, in any Laws (the costs with respect to
which shall be borne by the Purchaser), the Contractor shall be responsible for
the payment of any and all costs incurred as a result of the need to vary
design, drawings, plans or procedures to comply with any of the circumstances
set forth in this Article. The Contractor shall, before making any variations
from the designs, drawings, plans or procedures that may be necessitated by so
complying with any Laws and that would represent a material change to the
overall design of the System, give to the Purchaser written notice, specifying
the variations proposed to be made, and the reasons for making them. As of the
date hereof, neither Party has Actual Knowledge of any proposed changes in the
Laws which would necessitate any such variation.
F. The Contractor shall (i) give all notices required by any Laws to be given
to any authority and (ii) perform or permit the performance by authorized
persons of any inspection required by the said Laws, subject to Sub-Article
6(C).
G. Within 30 days after the date of execution of this Contract, the Contractor
will prepare and deliver to the Purchaser a detailed list of Permits that to its
knowledge are required to be obtained under current law in order to complete the
Work and shall update such list from time to time if it becomes aware of changes
in Permit requirements. Such list, as updated from time to time, shall set forth
the projected dates of filing for such Permits and an estimate of when such
Permits are expected to be obtained. Without limiting Contractor's liabilities
in respect of Sub-Articles 7(B), Contractor shall have no liability in respect
of the accuracy of the information furnished under this Sub-Article, except in
the case of gross negligence or willful misconduct.
ARTICLE 8 ROUTE SURVEY
--------- ------------
32
A. The Contractor shall conduct the Route Survey and select the cable route for
the System in accordance with the information in the Final Survey Report.
Contractor shall be permitted to make changes, at its discretion, to the route
selection, if necessary for operational reasons without additional cost to
Purchaser.
B. Any changes to the route selection requested by Purchaser (such as a change
of location for, or an addition of, a cable station) shall be treated as a
Contract Variation in accordance with Article 6 (Contract Variations).
ARTICLE 9 ACCEPTANCE
--------- ----------
A. General
1. The Acceptance Testing shall be performed by the Contractor. The Purchaser
and its designated representatives (including the Independent Engineer) may
observe, at their own expense, the Contractor's tests and review the test
results. Purchaser may request and conduct any additional tests, at its own
expense, but any delay caused by such process shall be a Force Majeure event.
2. Until the Date of Final Acceptance of the System or if a System Upgrade is
requested by Purchaser, the Date of Final Acceptance of such System Upgrade, the
Purchaser agrees to allow Contractor necessary access to all DLSs of the System.
3. The Purchaser shall issue a Certificate of Commercial Acceptance in
accordance with the provisions of Sub-Article 9(D)(1).
4. Once a DLS of the System, the System, or a System Upgrade is Ready for
Provisional Acceptance, the Purchaser shall issue a Certificate of Provisional
Acceptance; provided, that it is within the Purchaser's sole discretion as to
--------
whether to accept a DLS instead of the System.
5. Once the System or a System Upgrade is Ready for Final Acceptance, the
Purchaser shall issue a Certificate of Final Acceptance.
6. The Purchaser shall not unreasonably withhold or delay issuance of a
Certificate of Commercial Acceptance, a Certificate of Provisional Acceptance or
a Certificate of Final Acceptance.
7. The Contractor agrees that the Date of Provisional Acceptance or Commercial
Acceptance of the System will occur by February 29, 2000 (as such date may be
extended under Article 6 (Contract Variations), Article 17 (Force Majeure) or
otherwise under this Contract or by agreement of the Parties, the "Scheduled
System RFS Date").
8. The Date of Commercial Acceptance, Provisional Acceptance and Final
Acceptance, as the case may be, shall be deemed to have occurred with respect to
a DLS, the System, or a
33
System Upgrade if a Certificate of Commercial Acceptance, a Certificate of
Provisional Acceptance or a Certificate of Final Acceptance is issued with
respect thereto.
B. Notice of Acceptance or Rejection
1. Within thirty (30) days of receipt by Purchaser and Independent Engineer of
the Commissioning Report or Upgrade Commissioning Report, as the case may be,
the Purchaser must issue notification to the Contractor of the following:
(a) issuance of a Certificate of Provisional Acceptance in accordance with Sub-
Article 9(C); or
(b) rejection of a Certificate of Provisional Acceptance, but instead issuance
of a Certificate of Commercial Acceptance in accordance with Sub-Article
9(D) below; or
(c) rejection of the DLS, the System or System Upgrade in its existing
condition and issuance of neither a Certificate of Provisional Acceptance
nor a Certificate of Commercial Acceptance, with in the case of the System
or System Upgrade a written explanation of reasons for rejection (it being
understood that acceptance of a DLS instead of the System is at the sole
discretion of the Purchaser).
If the Purchaser (or the Independent Engineer on its behalf) fails to respond
with such notification within thirty (30) days, then the Date of Provisional
Acceptance of the DLS (subject to Purchaser's consent), the System or System
Upgrade shall be deemed to be the date such Commissioning Report or Upgrade
Commissioning Report, as the case may be, was received by the Purchaser.
2. On receipt of a notice from the Purchaser pursuant to Sub-Articles
9(B)(1)(b) or (c) above, the Contractor shall be entitled to address any
disputes and explain any discrepancies to the Purchaser regarding the results of
the Acceptance Testing. Unless Purchaser, for good cause, rejects such
explanation, it shall issue a new notice pursuant to Sub-Article 9(B)(1) above,
which shall be deemed to have been issued on the date of the original notice.
3. In case of rejection, and if the explanation by the Contractor as in Sub-
Article 9(B)(2) above is not accepted, for good cause, by the Purchaser, the
Contractor shall carry out the necessary corrective actions and will effect a
new series of Acceptance Testing ("Retesting"). After receipt by Purchaser and
Independent Engineer of the new Commissioning Report or Upgrade Commissioning
Report, as the case may be, describing the results of Retesting, the Purchaser
will be granted a new period of thirty (30) days to analyze the new Report
according to the provisions of Sub-Article 9(B)(1) and any new notice of the
Purchaser shall apply from the date the Purchaser receives such new
Commissioning Report or Upgrade Commissioning Report, as the case may be.
C. Provisional Acceptance
34
1. The Certificate of Provisional Acceptance may have annexed to it a list of
any outstanding deficiencies to be corrected by the Contractor.
2. The Contractor shall, as soon as reasonably practicable, correct such
deficiencies and complete the Work or Upgrade Work indicated on all such listed
items so as to comply in all material respects with the requirements of this
Contract, provided that the Purchaser allows Contractor the necessary access to
the DLS(s) as the Contractor needs to correct such deficiencies and complete the
Work or Upgrade Work. The Contractor shall give the Purchaser reasonable notice
of its requirement for such access.
D. Commercial Acceptance
1. A Certificate of Commercial Acceptance shall be issued by Purchaser with
respect to a DLS, the System or System Upgrade if the results of the Acceptance
Testing demonstrate that such DLS, the System or such System Upgrade does not
justify the issuance of a Certificate of Provisional Acceptance, but
nevertheless, such DLS, the System or such System Upgrade is Ready for
Commercial Acceptance; provided, that such acceptance of a DLS instead of the
--------
System shall be in the sole discretion of the Purchaser.
2. Each Certificate of Commercial Acceptance shall have annexed to it a
mutually agreed list of all outstanding items to be completed by the Contractor.
3. The Contractor shall, as soon as reasonably practicable, remedy the
outstanding items, provided that the Purchaser allows Contractor the necessary
access to the DLS(s) as the Contractor needs to remedy such outstanding items.
The Contractor shall give the Purchaser reasonable notice of its requirement for
such access. Notwithstanding the above, provided that Contractor has been
allowed access to the DLS(s) as required in Sub-Article 9(A)(2), the Contractor
shall continue to carry the risk of loss for any outstanding item until such
item is no longer outstanding.
4. When the outstanding items referenced in Sub-Article 9(D)(3) above have been
remedied, and the DLS(s) or System Upgrade is otherwise Ready for Provisional
Acceptance, the Purchaser will promptly issue a Certificate of Provisional
Acceptance; provided, that acceptance of a DLS instead of the System shall be in
--------
the sole discretion of the Purchaser.
5. The issuance of a Certificate of Commercial Acceptance with respect to a DLS
or System Upgrade shall in no way relieve the Contractor from its obligation to
provide a DLS or System Upgrade conforming with the Performance Requirements at
the time of the issuance of a Certificate of Commercial Acceptance.
E. Final Acceptance
1. Within thirty (30) days of the date of receipt by Purchaser and Independent
Engineer of the Final Commissioning Report, the Purchaser shall issue a
Certificate of Final Acceptance or reject such Report. If the Purchaser neither
issues a Certificate of Final Acceptance nor rejects
35
such Report within such thirty (30) day period, then the Date of Final
Acceptance of the System shall be deemed to be the date such Final Commissioning
Report was received by the Purchaser.
F. Title and Risk of Loss
1. If the Purchaser, in its sole discretion, chooses to accept a DLS prior to
accepting the System, then upon payment of all amounts listed in the Billing
Schedule with respect to a DLS (other than the Retainage with respect thereto)
and the issuance of a Certificate of Commercial Acceptance or a Certificate of
Provisional Acceptance with respect to such DLS by the Purchaser in accordance
with this Contract, title (free and clear of all liens other than those deriving
through or from the Purchaser) to such DLS shall vest in the Purchaser.
2. Upon (i) payment of all amounts listed in the Billing Schedule with respect
to the System (other than the Retainage) and (ii) the issuance of a Certificate
of Commercial Acceptance or a Certificate of Provisional Acceptance with
respect to the System by the Purchaser in accordance with this Contract, title
(free and clear of all liens other than those deriving through or from the
Purchaser) to the System shall vest in the Purchaser.
3. Upon payment of the Upgrade Price with respect to a System Upgrade and the
issuance of a Certificate of Commercial Acceptance or a Certificate of
Provisional Acceptance with respect to such System Upgrade by the Purchaser in
accordance with this Contract, title to such System Upgrade shall vest in the
Purchaser.
4. As from the date of vesting of title in a DLS, the System or a System
Upgrade, the Purchaser shall, except as set forth in the following sentence,
assume the risk of loss in respect of all parts of such DLS, the System or
System Upgrade and responsibility for its maintenance. As stated in Sub-Article
9(A)(2), the Contractor will be allowed access to such DLS, and, so long as the
Contractor has been allowed access to such DLS as may be required, the
Contractor shall continue to carry the risk of loss with respect of each item
outstanding under Sub-Article 9(C)(1) and 9(D)(2) until such item is no longer
outstanding.
ARTICLE 10 WARRANTY
---------- --------
A. The Contractor warrants that the System and each System Upgrade, including
its spares, shall be free from defects in supplies, workmanship and design for a
period of * commencing from the Date of Provisional Acceptance of the System or
such System Upgrade, as the case may be, (hereinafter "Warranty Period" and
"Upgrade Warranty Period"), with Ship Costs being covered for the first * of the
Warranty Period (the "Ship Period") and the Purchaser being responsible for all
Ship Costs thereafter.
1. During the Warranty Period for the System or the Upgrade Warranty Period for
a System Upgrade, the Contractor shall make good, by repair or replacement, at
its sole option, any defects in the System or such System Upgrade, as the case
may be, including any spares, which may become apparent or be discovered due to
imperfect workmanship, faulty design or faulty material supplied by the
Contractor, or any act, neglect or omission on the Contractors part.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
36
(a) If at any time within the Warranty Period or the Upgrade Warranty Period
for a System Upgrade any defect occurs which causes the System or such
System Upgrade, as the case may be, to fail to meet its overall Performance
Requirements, the Contractor shall repair or replace such part or parts. In
making such repairs, Contractor may make changes to the System or such
System Upgrade, as the case may be, or substitute equipment of later or
comparable design, provided the changes, modifications, or substitutions
under normal and proper use do not cause the System or such System Upgrade
as the case may be to fail to meet the Performance Requirements.
(b) The Contractor shall use reasonable efforts to minimize the period of time
that any DLS or the System is out of service for testing and repair. The
Purchaser agrees to cooperate with the Contractor to facilitate the
Contractor's repair activity.
(c) It is understood that if there is a problem on the System, the Purchaser
may immediately dispatch the maintenance authority to effect repairs. If
and to the extent that such problem is determined to be caused by a defect
in the System covered by this warranty, the Contractor shall reimburse the
Purchaser for its actual Non-Ship Costs incurred and, with respect to any
such repair relating to a defect identified in good faith by Purchaser in
writing prior to the end of the Ship Period, actual Ship Costs incurred.
(i) The Contractor shall be given advance notice and be entitled to have a
representative on board ship to observe at sea repairs and shall be given
the earliest possible notice of any such repair.
(ii) Subject to the foregoing and to Sub-Article 10(D), any repair by the
Purchaser shall not in any way diminish the Contractor's obligation under
the warranty. Any equipment discovered to be defective or faulty and
recovered during a warranty repair shall be returned to the Contractor at
its request.
(d) In the event that the Contractor fails to make the repair or to make
reasonable efforts to minimize the period of time that the System is out of
service for repair, the Purchaser may repair the System or the System
Upgrade and the Contractor shall reimburse the Purchaser for Non-Ship Costs
and, with respect to any such repair relating to a defect identified in
good faith by Purchaser in writing prior to the end of the Ship Period,
Ship Costs.
(i) The Contractor shall be given advance notice and be entitled to have a
representative on board ship to observe at sea repairs and shall be given
the earliest possible notice of any such repair.
(ii) Subject to the foregoing, any repair by the Purchaser shall not in any way
diminish the Contractor's obligation under the warranty. Any equipment
discovered to be defective or faulty and recovered during a warranty repair
shall be returned to the Contractor at its request.
2. Contractor shall bear the Ship Costs of only those repairs of the defects
identified in good faith by Purchaser in writing prior to the end of the Ship
Period. However, the Contractor shall
37
bear the Non-Ship Costs of each repair, replacement or improvement required
during the Warranty Period.
As used herein, "Ship Cost" means the costs of operating a vessel, including but
not limited to running and standing charges for the vessel (including but not
limited to labor charges for the vessel's crew, at sea insurance, port charges,
fuel and lube oils, consumables, cable loading, cable unloading, navigation and
maritime communications) as well as the costs associated with the use and
operation of a remotely operated vehicle and the tracked self-propelled burial
tool, and "Non-Ship Costs" means the costs of making a repair, including the
cost of components, equipment or materials requiring replacement, the cost of
any additional equipment necessary to effect the repair, the cost of making the
repair, including the cost of reburying any previously buried portion, the cost
of labor and engineering assistance or development required to make the repair
and all necessary associated costs, such as, but not limited to, shipping and
customs and services that may be required to make the repair, but excluding any
of the foregoing which are Ship Costs.
3. The Contractor shall effect all warranty repairs of the System and shall
supply all necessary repair materials. However, the Contractor may use, with the
consent of the Purchaser, which shall not be unreasonably withheld, the
materials needed to effect a repair from the Purchaser's available spare
materials. The Contractor shall promptly replace in kind such materials supplied
from the Purchaser's spare materials, or at the option of the Purchaser,
reimburse the Purchaser for such materials at its original purchase price. The
replacement of or reimbursement for such materials shall be made at a time
mutually agreed to by the Purchaser and the Contractor.
4. The Contractor warrants that services furnished hereunder will be performed
in a workmanlike manner using materials free from defects except when such
materials are provided by the Purchaser (it being understood that all materials
arranged for directly by Contractor, whether or not purchased in the name of
Purchaser, are not materials provided by the Purchaser). If such services prove
to be not so performed and Purchaser notifies the Contractor within six (6)
months from the completion of the service, the Contractor will promptly correct
the defect.
5. Any part which replaces a defective part during the applicable Warranty
Period or Upgrade Warranty Period, shall be subject to the remaining Warranty
Period and Ship Period, if any, or Upgrade Warranty Period, as the case may be,
of the part which was replaced. However, the Warranty Period shall never exceed
* from the Date of Provisional Acceptance of the System and the Upgrade Warranty
Period for any System Upgrade shall never exceed * from the Date of Provisional
Acceptance of such System Upgrade. Further, Ship Costs shall be included only
with respect to defects identified in good faith by Purchaser in writing during
the first * from the Date of Provisional Acceptance of the System.
B. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
38
C. The Contractor warrants that all Deliverable Software and Deliverable
Technical Materials are Year 2000 Compliant.
D. The warranties provided above in Sub-Articles 10(A) and (B) by the
Contractor shall not apply to defects or failures of performance, which result
from damage caused by acts or omissions of the Purchaser or its agents,
employees or representatives or third parties (other than the Contractor), or
which result from modifications, misuse, neglect, accident or abuse, repair,
storage or maintenance by other than the Contractor or its agents or use in a
manner not in accordance with the System Description or other causes set forth
in Article 12 (Purchaser's Obligations) or Article 17 (Force Majeure).
E. THE FOREGOING WARRANTY IS EXCLUSIVE AND IS IN LIEU OF ALL OTHER EXPRESS AND
IMPLIED WARRANTIES INCLUDING, BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY
AND FITNESS FOR A PARTICULAR PURPOSE WHICH ARE SPECIFICALLY DISCLAIMED. THE
PURCHASER'S SOLE AND EXCLUSIVE REMEDY WITH RESPECT TO DEFECTS COVERED BY THE
FOREGOING WARRANTY SHALL (EXCEPT AS SET FORTH IN SUB-ARTICLE B ABOVE) BE THE
CONTRACTOR'S OBLIGATION TO MAKE REPAIRS OR REPLACEMENTS AS SET FORTH IN THIS
ARTICLE; PROVIDED, THAT CONTRACTOR'S FAILURE TO SO PERFORM SHALL BE SUBJECT TO
--------
ARTICLE 13 HEREOF.
F. The Contractor shall, in accordance with its normal operating practices,
investigate any defective part or parts repaired or replaced pursuant to this
Article 10 to determine the type of defect and the cause of failure of the part
or parts. The Contractor shall provide a written report to the Purchaser on the
results of the investigation, if any.
G. Contractor warrants that the System and the Optional Branching Unit and/or
the Xxxx'x Crossing Branching Unit, as applicable, shall be designed in a manner
(i) adequate to support, without modification to the System, any extension
constructed by Contractor from the applicable branching unit and (ii) such that
any extension will have performance equal to or better than the System; provided
that (i) and (ii) are contingent upon each such extension falling within the
applicable distance parameters set forth in Appendix 6 (Technical Volume) and
Appendix 7 (Xxxx'x Crossing Appendix).
39
ARTICLE 11 CONTRACTOR SUPPORT
---------- ------------------
A. For a period of ten (10) years from the applicable Date of Provisional
Acceptance or Date of Commercial Acceptance of the System whichever is earlier,
the Contractor will make available to the Purchaser replacement parts and repair
service for the System as may be reasonably necessary for its operation,
maintenance or repair. Where identical parts cannot be supplied, the Contractor
shall provide fully compatible parts with characteristics equal or superior to
those originally provided by the Contractor. Such parts and services shall be
provided under commercially reasonable conditions of price and delivery.
B. Notwithstanding Sub-Article 11(A), if for any reason the Contractor or
Contractor's suppliers intend to cease or ceases manufacturing or having
manufactured identical or fully compatible replacement parts, the Contractor
shall use reasonable efforts to give one year's prior written notice to the
Purchaser to allow the Purchaser to order from the Contractor any required
replacement parts and shall provide full details of the arrangements to provide
equivalents.
ARTICLE 12 PURCHASER'S OBLIGATIONS
---------- -----------------------
A. Purchaser agrees to pay all amounts payable by it when due under this
Contract and to perform all of its other obligations under this Contract.
B. In the event the Purchaser establishes a branch office in any of the
relevant jurisdictions, the Purchaser shall be solely responsible to perform all
activities necessary to establish such branch office.
C. If any loss, damage, delay or failure of performance of the System or a
System Upgrade results from the Purchaser's failure to perform its obligations
under this Contract and results in an increase in the costs of performance or
the time required for performance of any of the Contractor's duties or
obligations under this Contract, the Contractor shall be entitled, as
appropriate, to (i) an equitable adjustment in the Contract Price or applicable
Upgrade Price, (ii) an equitable extension of time for completion of its Work or
the Upgrade Work, (iii) reimbursement for all such additional costs incurred,
and (iv) to the extent necessary in light of Purchaser's failure and the
adjustments made in accordance with clauses (i), (ii) and (iii) above, an
equitable adjustment of the Work and/or Upgrade Work.
1. The Contractor shall inform the Purchaser promptly of any occurrence covered
under this Sub-Article 12(C), and shall use reasonable efforts to minimize any
such additional costs or delay.
2. The Contractor shall promptly provide to the Purchaser an estimate of the
anticipated additional costs and time required to complete the Work or Upgrade
Work and request relief from contractual obligations or duties, as appropriate.
Purchaser shall, upon notification, make advance payment to Contractor for the
estimated amount of anticipated additional costs; provided that Purchaser may
--------
deposit such amount into the Dispute Account and Sub-Article 5(C)(5) shall
40
apply. Contractor shall without limiting Purchaser's obligations in the
foregoing sentence, discuss such costs with Purchaser upon Purchaser's request.
3. As soon as reasonably practicable after the actual costs become known to the
Contractor, the Contractor shall provide a statement of such actual costs to the
Purchaser.
4. If the estimated amount is greater than the amount of actual costs, then the
Contractor shall reimburse the Purchaser. If the amount of actual costs incurred
is greater than the estimated amount, then the Purchaser shall reimburse the
Contractor for any shortfall in accordance with Article 5 (Terms of Payment of
Purchaser).
ARTICLE 13 TERMINATION FOR DEFAULT
---------- -----------------------
A. Either Party may, by written Notice of Termination for Default, immediately
upon receipt or such later date as specified in the notice, terminate the whole
or any part of this Contract in any one of the following circumstances (each an
"Event of Default"):
1. In the case of the Purchaser, (a) if Contractor materially fails to comply
with the terms and conditions of this Contract and, if such failure occurs prior
to the Date of Commercial Acceptance or the Date of Provisional Acceptance, it
would not be reasonable to believe that the Contractor will be able to provide
the System which is Ready for Provisional Acceptance, within 200 days after the
Scheduled System RFS Date or (b) the Contractor fails to cause the System to be
Ready for Commercial Acceptance or Provisional Acceptance within 200 days after
the Scheduled System RFS Date;
2. If the other Party defaults on any of its payment obligations and does not
cure such default within a period of thirty (30) days (or such longer period as
the non-breaching Party may authorize in writing) after receipt of written
notice demanding cure (subject to dispute provisions);
3. If the other Party shall commence a voluntary case or other proceeding
seeking liquidation, reorganization or other relief with respect to itself or
its debts under any bankruptcy, insolvency or other similar law now or hereafter
in effect or seeking the appointment of a trustee, receiver, liquidator,
custodian or other similar official of it or any substantial part of its
property, or shall consent to any such relief or to the appointment of or taking
possession by any such official in an involuntary case or other proceeding
commenced against it, or shall make a general assignment for the benefit of
creditors, or shall fail generally to pay its debts as they become due, or shall
take any corporate action to authorize any of the foregoing;
4. If an involuntary case or other proceeding shall be commenced against the
other Party seeking liquidation, reorganization or other relief with respect to
it or its debts under any bankruptcy, insolvency or other similar law now or
hereafter in effect or seeking the appointment of a trustee, receiver,
liquidator, custodian or other similar official of it or any substantial part of
its property, and such involuntary case or other proceeding shall remain
undismissed and unstayed for a period of 60 days; or an order for relief shall
be entered against the other Party.
41
B. If this Contract is terminated by the Purchaser as provided in Sub-Article
13(A), the Purchaser, in addition to any other rights provided in this Article
and upon payment to Contractor of all monies due and owing as set forth in
clauses 1 and 2 of Sub-Article 13(C) below, may require the Contractor to
transfer title and deliver to the Purchaser in the manner and to the extent
directed by the Purchaser any completed equipment, material or supplies, and
such partially completed cable and materials, parts, tools, dies, jigs,
fixtures, plans, drawings, information, and contract rights (hereinafter
collectively "Manufacturing Materials") as the Contractor has had specifically
produced or specifically acquired for the performance of such part of this
Contract as has been terminated and which, if this Contract had been completed,
would have been required to be furnished to the Purchaser; and the Contractor
shall, upon the direction of the Purchaser, protect and preserve property in the
Contractor's possession in which the Purchaser has an interest.
C. If the Contract is terminated by Contractor as provided in Sub-Article
13(A), the Purchaser shall pay, in addition to any other damages payable
pursuant to Sub-Article 13(E) below, the total of:
1. the cost of settling and paying claims rising out of the termination of Work
under the contracts in orders, as provided in Sub-Article 13(C)(2) below which
are properly chargeable to the terminated portion of this Contract; and
2. the reasonable costs of settlement including accounting, legal, clerical and
other expenses necessary for the preparation of settlement claims and supporting
data with respect to the terminated portion of this Contract and for termination
and settlement of contracts thereunder, together with reasonable storage,
transportation and other costs incurred in connection with the protection,
preservation and disposition of property proper to this Contract.
D. Force Majeure events pursuant to Article 17 (Force Majeure) shall not
constitute a default or provide a basis for termination under this Article.
E. Regardless of any termination of this Contract as provided in Sub-Article
13(A), neither Party shall be relieved from any liability for damages or
otherwise which may have been incurred by reason of any breach of this Contract.
F. Without limitation to the foregoing, in the event that Purchaser terminates
this Contract pursuant to Sub-Article 13(A), the Contractor shall be liable to
Purchaser (without duplication) for the total of all costs and expenses
reasonably incurred by Purchaser in completing the Work or in correcting
deficiencies in the Work to the extent that the payments made to Contractor
pursuant to this Contract, together with such costs and expenses, exceed the
Contract Price.
ARTICLE 14 TERMINATION FOR CONVENIENCE
---------- ---------------------------
A. The performance of Work under this Contract may be terminated by the
Purchaser in whole, or in part, at its discretion. The Purchaser shall deliver
to the Contractor a written notice specifying the extent to which performance of
Work under this Contract is terminated, and the
42
date upon which such termination becomes effective (a "Notice of Termination").
Upon termination, the Purchaser will make payment to Contractor of all monies
due and owing as set forth in Sub-Article 14(D) below.
B. After receipt of such Notice of Termination, and except as otherwise
directed by the Purchaser, the Contractor shall:
1. Stop Work under this Contract on the date and to the extent specified in the
Notice of Termination;
2. Place no further orders or contracts for materials, services or facilities
except as may be necessary for completion of such portion of Work under this
Contract as is not terminated;
3. Use reasonable efforts to terminate all orders and contracts to the extent
that they relate to the performance of Work terminated by the Notice of
Termination;
4. Assign to the Purchaser, in the manner, at the time, and to the extent
directed by the Purchaser, all of the Contractor's rights, title and interest
under the orders and contracts so terminated;
5. Use reasonable efforts to settle all outstanding liabilities and all claims
arising out of such termination of orders and contracts, with the Purchaser's
approval or ratification to the extent required;
6. Transfer title and deliver to the Purchaser in the manner, at the time and
to the extent (if any) directed for the fabricated or unfabricated parts, work
in process, completed work, supplies and other material produced as a part of,
or acquired in connection with, the performance of the Work terminated by the
Notice of Termination;
7. Use reasonable efforts to sell, in the manner, at the time, to the extent
and at the price or prices directed or authorized by the Purchaser, any property
of the types referred to in Sub-Article 13(B)(6) above provided, however, that
-------- -------
the Contractor:
(a) shall not be required to extend credit to any buyer; and
(b) may acquire any such property under the conditions prescribed by and at a
price approved by the Purchaser;
and provided further that the net proceeds of any such transfer or disposition
-------- -------
shall be applied in reduction of any payments to be made by the Purchaser to the
Contractor under this Contract or, if no such payments are due, paid in such
other manner as the Purchaser may direct;
8. Complete performance of such part of the Work which was not terminated by
the Notice of Termination; and
43
9. Take such action as may be necessary, or as the Purchaser may reasonably
direct, for the protection and preservation of the property related to this
Contract which is in the Contractor's possession and in which the Purchaser has
acquired or may acquire an interest.
C. After such Notice of Termination, the Contractor shall submit to the
Purchaser a written termination claim. Such claim shall be submitted promptly,
but, unless otherwise extended, in no event later than six months from the
effective date of termination.
D. In the settlement of any such partial or total termination claim, the
Purchaser shall pay to the Contractor the total of:
1. all amounts invoiced in accordance with the Contract plus, for Work or
Supplies which have been done or provided but which have not been invoiced, an
amount calculated by reference to the prices set forth in the Provisioning
Schedule and to the amount of such Work or Supplies done or provided;
2. the cost of settling and paying claims arising out of the termination of
Work under the contracts in orders, as provided in Sub-Article 14(D)(4) below
which are properly chargeable to the terminated portion of this Contract; and
3. the reasonable costs of settlement including accounting, legal, clerical and
other expenses necessary for the preparation of settlement claims and supporting
data with respect to the terminated portion of this Contract and for termination
and settlement of contracts thereunder, together with reasonable storage,
transportation and other costs incurred in connection with the protection and
disposition of property proper to this Contract.
E. In arriving at the amount due to the Contractor under this Article 14, all
unliquidated payments made to the Contractor, any liability which the Contractor
may have to the Purchaser, and the agreed price for, or the proceeds of sale of
any materials, supplies or other things acquired by the Contractor or sold,
pursuant to the provisions of this Article 14, and not otherwise recovered by or
credited to the Purchaser shall be deducted.
F. The Purchaser may, from time to time, under such terms and conditions as
they prescribe approve partial payments and payments on account against costs
incurred by the Contractor in connection with the terminated portion of this
Contract. If such payments total in excess of the amount finally agreed or
determined to be due under this Article 14, such excess shall be refunded, upon
demand, by the Contractor to the Purchaser.
G. For a period of one year after final settlement under this Contract, the
Contractor shall preserve and make available to the Purchaser at reasonable
times at the Contractor's office, but without direct charge to the Purchaser,
all supporting books, records and documents required to be kept relating to the
terminated Work.
ARTICLE 15 SUSPENSION
---------- ----------
44
A. The Purchaser may, at its convenience, order the Contractor to suspend all
or part of the Work for such period of time as the Purchaser determines to be
appropriate. If, as a result of such Suspension, the Contractor incurs
additional costs or losses in the discharge of its responsibilities under this
Contract, and where such suspension, losses or costs are not caused by the
Contractor's act or omission and could not have been reasonably prevented by the
Contractor, the Contractor shall be allowed an equitable adjustment to the
Contract Price or the Provisioning Schedule in Appendix 1 and an equitable
extension in the time required for performance.
B. Upon the occurrence of:
(i) an Event of Default by the Purchaser;
(ii) any transfer prior to the Date of Final Acceptance of any portion of the
System except in accordance with Article 37; or
(iii) any supplement executed by a Transferee shall not be in full force and
effect;
the Contractor, in addition to any other rights provided in Article 13, may
suspend performance of its obligations and all Work and (in the case of clause
(i)) Upgrade Work.
C. Every thirty (30) days, or such shorter period as the Parties shall mutually
agree, during the period of Suspension, the Parties shall meet formally and
review the circumstances surrounding the Suspension including without
limitation, the anticipated date of re-commencing Work.
D. Thereafter, if the Suspension continues for a total of one hundred and
eighty (180) days, the Contractor may terminate the Contract by notice to the
Purchaser and the Contract shall be deemed to have been terminated by Purchaser,
effective on the date of Contractor's notice, in accordance with Sub-Article
13(A) and the remaining provisions of Article 13 shall apply.
ARTICLE 16 TITLE AND RISK OF LOSS
---------- ----------------------
A. Except as provided in Article 18 (Intellectual Property), Article 20
(Safeguarding of Information and Technology) and Article 21 (Export Control),
title to all Supplies provided by the Contractor hereunder for incorporation in
or attachment to a DLS shall pass to and vest in the Purchaser in accordance
with Article 9 (Acceptance). Risk of loss or damage to all Supplies provided by
the Contractor for incorporation in or attachment to such DLS shall pass to and
vest in the Purchaser in accordance with Article 9. Upon termination of this
Contract pursuant to Article 13 (Termination for Default) or 14 (Termination for
Convenience), the Purchaser may require, upon full payment of all amounts due
thereunder (provided that, without limiting Purchaser's obligation to make any
--------
such payment, if this Contract is terminated by Purchaser because of a
Bankruptcy Event full payment shall not be required prior to the transfer of
title), that title to the equipment, materials and supplies, which has not
previously passed to the Purchaser, pass to the Purchaser, free and clear of all
liens, claims, charges and other encumbrances other than those deriving through
Purchaser.
45
B. Upon the passage of title in accordance with the terms of Article 13 (except
a transfer described in the proviso of the last sentence of Sub-Article 16(A)),
the Contractor warrants that all parts, materials, and equipment to which title
has passed will be free and clear of all liens, claims, charges and other
encumbrances other than those deriving through the Purchaser.
ARTICLE 17 FORCE MAJEURE
---------- -------------
A. The Contractor shall not be responsible for any loss, damage, delay or
failure of performance resulting directly or indirectly from any cause which is
beyond its reasonable control ("Force Majeure"), including but not limited to:
delay in obtaining or failure to obtain any Permits (subject to the provisions
of Sub-Article 7(D)); acts of God or of the public enemy; acts or failure to act
of any governmental authority; war or warlike operations, civil war or
commotion, mobilizations or military call-up, and acts of similar nature;
revolution, rebellions, sabotage, and insurrections or riots; fires, floods,
epidemics, quarantine restrictions; strikes, and other labor actions; freight
embargoes; unworkable weather; trawler or anchor damage; damage caused by other
marine activity such as fishing, marine research and marine development; acts or
omissions of transporters; or the acts or failure to act of any of the
Purchaser, of its representatives or agents, provided that (i) a loss by
--------
Contractor of employees (other than by reasons of Force Majeure), (ii) strikes
and other labor actions involving the Contractor's own work force, (iii) the
first 5 days of unworkable weather (unless any such day occurs during the 30
days immediately preceding the then Scheduled System RFS Date), (iv) the failure
(other than by reason of force majeure) of any subcontractor, supplier or
transporter to perform its obligations to Contractor (including on account of
insolvency) unless such supplies or transportation or other services are
generally unavailable in the marketplace, (v) the unavailability of any raw
materials or components, unless such raw materials or components are generally
unavailable in the marketplace or are unavailable by reason of force majeure or
(vi) any increase in Contractor's costs, shall not in and of itself constitute
Force Majeure.
B. If any such Force Majeure causes an increase in the time required for
performance of any of its duties or obligations, the Contractor shall be
entitled to an equitable extension of time for completion of the Work or the
Upgrade Work, as the case may be.
C. Increase in cost due to Purchaser will be as provided for in Article 12,
Purchaser's Obligations.
D. The Contractor shall inform the Purchaser promptly with written
notification, and in all cases within fourteen (14) days of discovery and
knowledge, of any occurrence covered under this Article and shall use its
reasonable efforts to minimize such additional delays. The Contractor shall
promptly provide an estimate of the anticipated time required to complete the
Work or the Upgrade Work. Contractor shall be entitled to an extension of time
equal to at least one day for each day of delay resulting from the Force Majeure
condition.
E. Within thirty (30) days of receipt of such a notice from Contractor, the
Purchaser and the Independent Engineer may provide a written response. The
absence of a response shall be deemed as acceptance of Contractor's notice and
request for additional time.
46
F. If a Force Majeure continues for a total of two hundred (200) days, either
Party may terminate the Contract by notice to the other and the Contract shall
be deemed to have been terminated by Purchaser, effective on the date of the
terminating Party's notice, in accordance with Sub-Article 14(A) and the
remaining provisions of Article 14 shall apply to such termination.
ARTICLE 18 INTELLECTUAL PROPERTY
---------- ---------------------
A. Ownership
All right, title, and interest in and to all Intellectual Property (excluding
Project Patent Rights) created or developed by Contractor in the course of its
performance under this Contract that is (a) specifically and exclusively
applicable to the System or a System Upgrade; and (b) either (i) embodied in
Deliverable Technical Material (as that term is defined in Sub-Article 18(B)
below) or (ii) embodied in the System or a System Upgrade (the "Project
Intellectual Property"), is and shall remain the sole property of Purchaser.
All right, title and interest in and to all Intellectual Property created or
developed by Contractor before commencing its performance under this Contract,
or created or developed by Contractor exclusively in connection with activities
other than its performance under this Contract, or created or developed by
Contractor in the course of its performance under this Contract that is not
Project Intellectual Property, and all Project Patent Rights (collectively, the
"Contractor Intellectual Property"), is and shall remain the sole property of
Contractor. Unless otherwise expressed in this Contract, no license is implied
or granted herein to Purchaser to any Contractor Intellectual Property by virtue
of this Contract, nor by the transmittal or disclosure of any such Contractor
Intellectual Property to Purchaser. Any Contractor Intellectual Property
disclosed, furnished, or conveyed to Purchaser that is marked as "Proprietary"
or "Confidential" (or if transmitted orally is identified as being proprietary
or confidential in a subsequent writing) shall be treated in accordance with the
provisions of Article 20 (Safeguarding of Information and Technology). As used
herein, "Intellectual Property" means any information, computer or other
apparatus programs, software, specifications, drawings, designs, sketches,
tools, market research or operating data, prototypes, records, documentation,
works of authorship or other creative works, ideas, concepts, methods,
inventions, discoveries, improvements, or other business, financial and/or
technical information (whether or not protectable or registrable under any
applicable intellectual property law). As used herein, "Project Patent Rights"
means all inventions, discoveries, methods and improvements of a patentable
nature created or developed by Contractor in the course of its performance under
this Contract. Project Intellectual Property will include the materials to be
listed in a Schedule to be created mutually by the Parties within thirty (30)
days of execution of this Contract, as it may be amended from time to time by
mutual agreement of the Parties.
B. Licenses
Contractor shall furnish to Purchaser, upon the transfer of title to any portion
of the System or a System Upgrade pursuant to Article 9, copies of all technical
information, specifications, drawings, designs, sketches, tools, operating data,
records, documentation and/or other types of engineering or technical data or
information reasonably relating to the operation, maintenance or
47
repair of each component of such portion of the System or System Upgrade as
delivered by Contractor (the "Deliverable Technical Material"). Contractor
grants to Purchaser a perpetual, royalty-free, non-transferable (except under
the circumstances specified in Sub-Article 18(F) below) license to use and
reproduce those Deliverable Technical Materials owned, controlled, or developed
by Contractor and all Contractor Intellectual Property included in or necessary
to use all the Deliverable Technical Materials for purposes of fulfilling
Purchaser's obligations under this Contract and using and operating the System
(as upgraded by any System Upgrades) supplied by Contractor with the right to
employ third parties (under appropriate written obligations respecting
confidentiality) to assist Purchaser in fulfilling its obligations under this
Contract and in using and operating the System (as upgraded by any System
Upgrades), but with no right to sublicense. Contractor grants to Purchaser a
perpetual, royalty-free, non-transferable (except under the circumstances
specified in Sub-Article 18(F) below) license to use and reproduce those
portions of Deliverable Technical Materials owned or controlled by third parties
(but only to the extent of any rights which may have been granted to Contractor
by such third parties) for the purpose of fulfilling Purchaser's obligations
under this Contract and using and operating the System supplied by Contractor
with the right to employ third parties (under appropriate written obligations
respecting confidentiality) to assist Purchaser in fulfilling its obligations
under this Contract and in using and operating the System (as upgraded by any
System Upgrades), but with no right to sublicense. Except as set forth in this
provision, no license under Contractor's patents, copyrights, trade or service
marks, trade secrets or other intellectual property rights protectable under law
in the United States or any foreign country is granted to Purchaser. It is
expressly understood that it shall not be a violation of this license for
Purchaser, on its own behalf or through third parties (under appropriate written
obligations respecting confidentiality) specifically employed for the purpose,
to use and reproduce Deliverable Technical Material that is not Project
Intellectual Property to modify the System (as upgraded by any System Upgrades)
or connect the System (as upgraded by any System Upgrades) to other systems,
provided that Purchaser may not use the Deliverable Technical Materials that is
not Project Intellectual Property in achieving such modification or
interconnection for any purpose other than determining the technical
configuration, systems interface and/or interoperability requirements of the
System (as upgraded by any System Upgrades) as delivered by Contractor (subject
to the rights of third parties therein and thereto), and subject to the
limitations on Contractor's obligations as set forth in Articles 10(D) and 19(A)
concerning any such modification or interconnection.
C. Deliverable Software
Contractor shall furnish to the Purchaser, upon transfer of title to any portion
of the System or System Upgrade pursuant to Article 9, copies of all computer or
other apparatus programs and software, in executable form, and related
documentation relating to the operation, maintenance, or repair of the computer
systems of such portion of the System or System Upgrade, as the case may be, as
delivered by Contractor (the "Deliverable Software"). In the case of Contractor
Intellectual Property, such copies of programs and software shall consist solely
of executable code provided in offline media (e.g., tapes, or diskettes) for
restoration purposes, sufficient to operate, maintain or repair the computer
systems of such portion of the System or System Upgrade, as the case may be, as
delivered by Contractor, and in the case of Project Intellectual Property, such
programs and software shall be delivered in both source and object code forms.
48
Contractor shall furnish to Purchaser, from time to time during the Warranty
Period or any Upgrade Warranty Period, copies of all computer or other apparatus
programs and software, in executable form (and in the case of Project
Intellectual Property, in source code form), and related documentation that
Contractor may develop to correct errors or to maintain Deliverable Software
previously furnished to Purchaser, which shall also be treated as Deliverable
Software for purposes of this Contract upon delivery thereof to Purchaser.
Contractor grants to Purchaser a perpetual, royalty-free, non-transferable
(except under the circumstances specified in Sub-Article 18(F) below) license to
use and reproduce the Deliverable Software Materials owned, controlled, or
developed by Contractor for the purpose of fulfilling Purchaser's obligations
under this Contract and using and operating the System (as upgraded by any
System Upgrades) supplied by Contractor with the right to employ third parties
(under appropriate written obligations respecting confidentiality) to assist
Purchaser in fulfilling its obligations under this Contract and in using and
operating the System (as upgraded by any System Upgrades), but with no right to
sublicense. Contractor grants to Purchaser a perpetual, royalty-free, non-
transferable (except under the circumstances specified in Sub-Article 18(F)
below) license to use and reproduce those portions of Deliverable Software owned
or controlled by third parties (but only to the extent of any rights which may
have been granted to Contractor by such third parties) for the purpose of
fulfilling Purchaser's obligations under this Contract and using and operating
the System (as upgraded by any System Upgrades) supplied by Contractor with the
right to employ third parties (under appropriate written obligations respecting
confidentiality) to assist Purchaser in fulfilling its obligations under this
Contract and in using and operating the System (as upgraded by any System
Upgrades), but with no right to sublicense. These licenses shall be limited to
the right to use Deliverable Software that is not Project Intellectual Property
only with the particular type of computer equipment or substantially similar
replacement equipment for which such Deliverable Software was provided in the
System (as upgraded by any System Upgrades) as supplied by Contractor.
1. Confidentiality
Purchaser shall keep the Deliverable Software that is not Project Intellectual
Property confidential in accordance with Article 20 (Safeguarding of Information
and Technology) and Article 21 (Export Control) to the extent that such
Deliverable Software is designated as Confidential Information by its owner and
agrees to use its best efforts to see that its employees, consultants, and
agents, and other users of such software, comply with the provisions of this
Contract. Purchaser also agrees to refrain from taking any steps, such as
reverse assembly or decompilation, to derive a source code equivalent of any
object code that is furnished by Contractor, provided that Contractor continues
to maintain the Deliverable Software that is not Project Intellectual Property
in accordance with the terms of a support and maintenance agreement to be
entered into on such terms to be agreed upon by the Parties, which terms shall
in all events contain assurances of support and maintenance at least as
favorable to Purchaser as those contained in the Operating, Administration and
Maintenance Agreement concerning AC-1 or is willing and able to enter into an
agreement to maintain the Deliverable Software upon terms reasonably comparable
to the pertinent terms of the initial agreement to be entered into by the
Parties with regard to support and maintenance after the expiration or
termination thereof or does not go insolvent or bankrupt to thereby *. In the
case of insolvency or bankruptcy of Contractor, Purchaser shall limit any
derivation of a source code equivalent to that portion of the Deliverable
Software that is
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
49
Contractor Intellectual Property. Purchaser shall not under any circumstances
take any steps to derive a source code equivalent from that portion of the
Deliverable Software comprising commercial, off-the-shelf software developed or
provided by third parties.
2. Backup Copies
Purchaser may make and retain two archive copies in executable form of the
Deliverable Software that is not Project Intellectual Property. Any copy will
contain the same copyright notice and proprietary markings as are on the
original software and shall be subject to the same restrictions as the
originals.
3. Termination of Software Licenses
In the event of (i) use by the Purchaser of Deliverable Software that is not
Project Intellectual Property in a manner other than that permitted in Sub-
Article 18(C) or (ii) any other material breach of this Article 18 by Purchaser
that in either event is not cured within sixty (60) days from receipt by
Purchaser of written notice of such impermissible use or breach, Contractor, at
its option, may terminate the rights granted to Purchaser pursuant to this
Article, upon written notice to Purchaser, which termination shall take effect
no sooner than sixty (60) days following receipt by Purchaser of a subsequent
written notice of termination. Upon termination, Purchaser shall either return
or destroy, at Contractor's option, all copies of Deliverable Software that is
not Project Intellectual Property furnished under this Contract.
4. Indemnification
In the event of (i) use by Purchaser of Deliverable Software that is not Project
Intellectual Property furnished hereunder other than that permitted in Sub-
Article 18(C) or (ii) any other material breach of this Article 18 by Purchaser,
the Purchaser shall indemnify and hold Contractor harmless from any and all
third party claims resulting therefrom whether arising from a defect in the
software or otherwise.
D. Trademarks, Tradenames, etc.
No rights are granted herein to either Party to use any identification (such as,
but not limited to tradenames, trademarks, service marks or symbols, and
abbreviations, contractions, or simulations thereof) owned or used by the other
Party or its parent company or its affiliates to identify itself or its
affiliates or any of its products or services. Each Party agrees that it will
not, without the prior written permission of the other Party, use such
identification in advertising, publicity, packaging, labeling, or in any other
manner to identify itself or any of its products, services, or organizations, or
represent directly or indirectly that any product, service, or organization of
it is a product, service, or organization of the other Party or its affiliates,
or that any product or service of a Party is made in accordance with or utilizes
any intellectual property of the other Party or its affiliates.
E. DISCLAIMER, LIMITATION OF LIABILITY
CONTRACTOR REPRESENTS THAT ANY INFORMATION OR INTELLECTUAL PROPERTY FURNISHED IN
CONNECTION WITH THIS CONTRACT SHALL BE TRUE AND ACCURATE TO THE BEST OF ITS
KNOWLEDGE AND BELIEF, BUT
50
CONTRACTOR SHALL NOT BE HELD TO ANY LIABILITY FOR UNINTENTIONAL ERRORS OR
OMISSIONS THEREIN. EXCEPT AS EXPRESSLY PROVIDED, CONTRACTOR MAKES NO
REPRESENTATIONS OR WARRANTIES, EXPRESSLY OR IMPLIEDLY. BY WAY OF EXAMPLE, BUT
NOT OF LIMITATION, CONTRACTOR AND ITS PARENT COMPANY AND AFFILIATES MAKES NO
REPRESENTATIONS OR WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR
PURPOSE, OR THAT THE USE OF INFORMATION OR INTELLECTUAL PROPERTY DISCLOSED OR
PROVIDED HEREUNDER WILL NOT INFRINGE ANY PATENT OR OTHER INTELLECTUAL PROPERTY
RIGHT OF A THIRD PARTY. EXCEPT AS OTHERWISE PROVIDED IN THIS CONTRACT,
CONTRACTOR AND ITS PARENT AND AFFILIATES SHALL NOT BE HELD TO ANY LIABILITY WITH
RESPECT TO ANY CLAIM BY PURCHASER OR ANY THIRD PARTY CLAIM AGAINST PURCHASER ON
ACCOUNT OF, OR ARISING FROM, PURCHASER'S USE OF INFORMATION OR INTELLECTUAL
PROPERTY DISCLOSED OR PROVIDED BY CONTRACTOR.
F. Transferability
The licenses granted to Purchaser by Contractor in the Deliverable Technical
Materials and Deliverable Software are personal and non-transferable, except
that Purchaser may assign or transfer such licenses to an affiliated entity
under common control with the Purchaser or to any entity succeeding to
Purchaser's entire interest in the System (as upgraded by any System Upgrades)
as a result of reorganization or restructuring of the Purchaser or in the event
of a change of control of the Purchaser.
G. *
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
51
ARTICLE 19 INFRINGEMENT
---------- ------------
A. The Contractor agrees to defend or settle at its own expense all suits for
infringement of any patent, copyright, trademark or other form of intellectual
property right in any country of the world, for the use and operation of the
System (as upgraded by any System Upgrades) as supplied by Contractor and for
any component part thereof or material or equipment used therein (or the
manufacture of any material or the normal use thereof) provided by the
Contractor or on its behalf pursuant to this Contract and will hold the
Purchaser harmless from all expense of defending any such suit and all payments
for final judgment assessed on account of such infringement, except such
infringement or claim arising from:
1. The Contractor's adherence to the Purchaser's directions in the design and
configuration of the System (as upgraded by any System Upgrades) or to use
materials, parts or equipment of the Purchaser's selection; or
2. Such material, parts or equipment furnished to the Contractor by the
Purchaser, other than in each case, items of the Contractor's design or
selection or the same as any of the Contractor's commercial merchandise or in
processes or machines of the Contractor's design or selection used in the
manufacture of such standard products or parts; or
3. Use of the System (as upgraded by any System Upgrades) or the materials,
parts or equipment furnished by Contractor other than for the purposes indicated
in, or reasonably to be inferred from, this Contract or in conjunction with
other products; or
4. Modification of the System (as upgraded by any System Upgrades) or the
materials, parts or equipment furnished by the Contractor, or connection of the
System to another system by any person or entity other than Contractor, without
prior expressed written approval by Contractor.
B. The Purchaser will, at its own expense, defend all suits against the
Contractor for such excepted infringement and hold the Contractor harmless from
all expense of defending any such suit and from all payments by final judgment
assessed against the Contractor on account of such excepted infringement.
C. The Contractor and the Purchaser agree to give each other prompt written
notice of claims and suits for infringement, full opportunity and authority to
assume the sole defense, including appeals and, upon request and at its own
expense, the other agrees to furnish all information and assistance available to
it for such defense.
52
D. If all or any portion of the System (as upgraded by any System Upgrades) or
any material, part or equipment provided by the Contractor or on its behalf is
held to constitute an infringement (excluding such excepted infringements
specified in Sub-Article 19(A)) and is subject to an injunction restraining its
use or any order providing for its delivery up to or destruction, or if in
respect of any such claim of infringement the Contractor deems it advisable to
do so, the Contractor shall at its own expense either:
1. Procure for the Purchaser the right to retain and continue to use the
System, the affected portion thereof, or any such material, part or equipment
without interruption for the Purchaser;
2. Replace or modify the System, the affected portion thereof, or any material,
part or equipment so that it becomes noninfringing while continuing to meet the
Performance Requirements or
3. If the remedies specified in Sub-Articles 19(D)(1) an 19(D)(2) are not
feasible, refund to the Purchaser the full purchase price paid for the System,
the affected portion thereof, or any material, part or equipment found to be
infringing.
E. In no event shall the Purchaser make any admission or settle any claim in
relation with any claim for infringement without Contractor's consent.
ARTICLE 20 SAFEGUARDING OF INFORMATION AND TECHNOLOGY
---------- ------------------------------------------
A. In performance of this Contract, it may be mutually advantageous to the
Parties hereto to share certain specifications, designs, plans, drawings,
software, market research or operating data, prototypes, or other business,
financial, and or/technical information related to products, services, or
systems which are proprietary to the disclosing Party or its affiliates (and in
the case of Contractor, Contractor's parent company) (together with this
Contract and related documents, "Information"). The Parties recognize and agree
that Information includes information that was supplied in contemplation hereof
prior to execution of this Contract, and further agree that Information includes
information in both tangible and intangible form.
B. Unless such Information was previously known to the Party receiving such
Information free of any obligation to keep it confidential, or such Information
has been or is subsequently made public through other than unauthorized
disclosure by the receiving Party or is independently developed by the receiving
Party (as documented by the records of the receiving Party), it shall be kept
confidential by the Party receiving such Information, shall be used only in the
performance of this Contract, and may not be used for any other purposes except
upon such terms as may be agreed upon in writing by the Party owning such
Information. The receiving Party may disclose such Information to other persons,
upon the furnishing Party's prior written authorization, but solely to perform
acts which this Article expressly authorizes the receiving Party to perform
itself and further provided such other person agrees in writing (a copy of which
writing will be provided to the furnishing Party at its request) to the same
conditions respecting disclosure and use of Information contained in this
Article and to any other reasonable conditions requested by the furnishing
Party. Nothing herein shall prevent a Party from disclosing
53
Information (a) upon the order of any court or administrative agency, (b) upon
the request or demand of, or pursuant to any regulation of, any regulatory
agency or authority, (c) to the extent reasonably required in connection with
the exercise of any remedy hereunder and (d) to a Party's legal counsel or
independent auditors.
C. The Purchaser may disclose Information to its lenders and their
representatives in connection with obtaining financing for the System, provided
that each such lender or third party enters into a confidentiality agreement
containing terms and conditions similar to those in this Contract. Any such
disclosure of Information shall be subject to the restrictions in Sub-Article
20(B).
ARTICLE 21 EXPORT CONTROL
---------- --------------
The Parties acknowledge that any products, software, and technical information
(including, but not limited to, services and training) provided by either Party
under this Contract are or may be subject to export laws and regulations of the
United States and destination countries and any use or transfer of such
products, software and technical information must be authorized under those
Laws. The Parties agree that they will not use, distribute, transfer or transmit
the products, software or technical information (even if incorporated into other
products) except in compliance with export Laws. If requested by either Party,
the other Party agrees to sign all necessary export-related documents as may be
required to comply with export Laws.
ARTICLE 22 LIQUIDATED DAMAGES
---------- ------------------
A. If the System is not Ready for Commercial Acceptance or Provisional
Acceptance by the Scheduled System RFS Date, as it may have been extended under:
1. Article 6 (Contract Variations);
2. Article 17 (Force Majeure); or
3. Other arrangements as agreed between the Purchaser and the Contractor;
then Contractor shall pay to Purchaser for each day of delay, for up to 200
days, by way of pre-estimated and liquidated damages for the delay and not as a
penalty, an amount equal to * of the Contract Price (less Taxes) for the
System; provided, that, if Purchaser, in its sole discretion, elects to accept a
DLS prior to acceptance of the System, the Contract Price (less Taxes), for
purposes of this Sub-Article 22(A), shall be reduced by that portion of the
Contract Price (less Taxes) allocable (which allocation shall be determined in
good faith by mutual agreement of the Parties) to such DLS.
B. If a System Upgrade is not Ready for Commercial Acceptance or Provisional
Acceptance by the Scheduled Upgrade Date, as it may have been extended under:
1. Article 6 (Contract Variations);
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
54
2. Article 17 (Force Majeure); or
3. Other arrangements as agreed between the Purchaser and the Contractor;
then Contractor shall pay to Purchaser for each day of delay, for up to 90 days,
by way of pre-estimated and liquidated damages for the delay and not as a
penalty, an amount equal to * of the Initial Upgrade Price for such System
Upgrade.
ARTICLE 23 LIMITATION OF LIABILITY/INDEMNIFICATION
---------- ---------------------------------------
A. NOTWITHSTANDING ANY OTHER PROVISION IN THIS CONTRACT, AND IRRESPECTIVE OF
ANY FAULT, NEGLIGENCE OR GROSS NEGLIGENCE OF ANY KIND, IN NO EVENT SHALL EITHER
PARTY OR ANY OF ITS DIRECTORS, OFFICERS, EMPLOYEES OR AGENTS BE LIABLE FOR ANY
CONSEQUENTIAL, INCIDENTAL, INDIRECT, RELIANCE OR SPECIAL (INCLUDING PUNITIVE)
DAMAGES, INCLUDING, BUT NOT LIMITED TO, LOSS OF REVENUE, LOSS OF BUSINESS
OPPORTUNITY OR THE COSTS ASSOCIATED WITH THE USE OF RESTORATION FACILITIES
RESULTING FROM ITS FAILURE TO PERFORM PURSUANT TO THE TERMS AND CONDITIONS OF
THIS CONTRACT.
B. EXCEPT AS SET FORTH BELOW IN THE LAST TWO SENTENCES OF THIS SUB-ARTICLE
23(B), THE CONTRACTOR'S MAXIMUM AGGREGATE LIABILITY, WHETHER IN TORT, CONTRACT
OR OTHERWISE, EXCEPT FOR CLAIMS RELATING TO SYSTEM UPGRADES, SHALL NOT EXCEED *
OF THE CONTRACT PRICE. THE CONTRACTOR'S MAXIMUM AGGREGATE LIABILITY FOR CLAIMS
RELATING TO SYSTEM UPGRADES (IF CONTRACTOR CAN PROVE THAT THE SYSTEM WAS
DESIGNED WITH SUFFICIENT TRANSMISSION MARGIN AND THUS SUCH CLAIMS DO NOT ARISE
UNDER CLAUSE (ii) OF SUB-ARTICLE 10(B)) SHALL NOT EXCEED * OF THE APPLICABLE
UPGRADE PRICE. THE FOREGOING LIMITATION SHALL NOT APPLY TO CLAIMS UNDER SUB-
ARTICLES 19(A) AND 23(C). IF CONTRACTOR CANNOT PROVE THAT THE SYSTEM WAS
DESIGNED WITH SUFFICIENT TRANSMISSION MARGIN FOR A SYSTEM UPGRADE, THE
CONTRACTOR'S MAXIMUM AGGREGATE LIABILITY FOR CLAIMS ARISING UNDER CLAUSE (ii) OF
SUB-ARTICLE 10(B) SHALL NOT EXCEED *.
C. Contractor, at its expense, shall defend, indemnify and hold harmless
Purchaser, its agents, subcontractors and employees against any and all claims,
demands, and judgments for losses due to any act or omission, arising out of, or
in connection with this Contract or, prior to risk of loss passing to Purchaser,
the operation and maintenance of the System, to the extent such losses were
caused by the negligence or willful misconduct of the Contractor, its
subcontractors, employees or agents. The defense, indemnification and save
harmless obligation is specifically conditioned on the following: (i) Purchaser
providing prompt notification in writing of any such claim or demand when it
obtains Actual Knowledge thereof, unless such failure shall not have materially
impaired Contractor's ability to defend against such claim; (ii) Contractor
having
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
55
control of the defense of any such action, claim or demand and of all
negotiations for its settlement or compromise; and (iii) Purchaser cooperating,
at Contractor's expense, in a reasonable way to facilitate the defense of such
claim or demand or the negotiations for its settlement.
D. Purchaser, at its expense, shall defend, indemnify and hold harmless
Contractor, its agents, subcontractors and employees against any and all claims,
demands, and judgments for losses due to any act or omission, arising out of, or
in connection with this Contract or, after risk of loss passes to Purchaser, the
operation or maintenance of the System, to the extent such losses were caused by
the negligence or willful misconduct of the Purchaser, its subcontractors,
employees or agents (other than Contractor). The defense, indemnification and
save harmless obligation is specifically conditioned on the following (i)
Contractor providing prompt notification in writing of any such claim or demand
when it obtains Actual Knowledge thereof, unless such failure shall not have
materially impaired Purchaser's ability to defend against such claim; (ii)
Purchaser having control of the defense of any such action, claim or demand and
of all negotiations for its settlement or compromise; and (iii) Contractor
cooperating, at Purchaser's expense, in a reasonable way to facilitate the
defense of such claim or demand or the negotiations for its settlement.
ARTICLE 24 COUNTERPARTS
---------- ------------
This Contract may be signed in any number of counterparts, each of which shall
be an original, with the same effect as if the signatures thereto and hereto
were upon the same instrument.
ARTICLE 25 DESIGN AND PERFORMANCE RESPONSIBILITY
---------- -------------------------------------
A. The Contractor shall be solely responsible for the design of and for all
details of the System and the System Upgrades and for the adequacy thereof.
B. The Contractor's responsibility for design of the System and the System
Upgrades shall not in any way be diminished nor shall the Contractor's design
approach be restricted or limited by the Purchaser's acceptance of the
Contractor's guidance or recommendations as to engineering standards and design
specifications, or by the Purchaser's suggestions or recommendations on any
aspect of the design.
C. Purchaser shall use reasonable efforts in assisting the Contractor to obtain
in a timely manner accurate information required for the Contractor to perform
the Work and the Upgrade Work, which Contractor cannot expeditiously and cost-
effectively obtain from any source other than the Purchaser.
ARTICLE 26 PRODUCT CHANGES
---------- ---------------
The Contractor may at any time make changes to the System or System Upgrades
furnished pursuant to this Contract, or modify the drawings and published
specifications relating thereto, or substitute equipment of later design,
provided the changes, modifications, or substitutions under
56
normal and proper use do not impact upon the form, fit, expected life or
function of the System as provided in the System Performance Requirements.
ARTICLE 27 RISK AND INSURANCE
---------- ------------------
A. The Contractor shall at all times maintain, after the date which is 30 days
from the date hereof, and upon request, the Contractor shall furnish the
Purchaser with certificates, or other reasonable evidence, that Contractor
maintains, the following insurance or has adequate self-insurance (other than as
required to comply with any statutory insurance requirements); provided, that
--------
the following insurance coverages may be combined or in different form so long
as Contractor maintains insurance consistent with the following requirements:
1. Workmen's Compensation and Employers Liability Insurance (with a limit of
not less than * for any one incident or series of incidents arising from
one event or such higher limit as may be required by the laws of any
jurisdiction) covering the officers and employees of the Contractor for all
compensation or other benefits required of the Contractor by the laws of any
nation or political sub-division thereof to which the Contractor and its
operations under this Contract are subject in respect of injury of death of any
such employee.
2. Comprehensive General Public Liability Insurance, covering personal injury
and/or property damage, with combined single limits of not less than *
for claims of injury or death of any persons or loss of or damage to property
resulting from any one accident. This insurance to be extended to provide Marine
Comprehensive General Liability including liabilities arising out of the
operation of subsea equipment.
3. Comprehensive Automobile Liability insurance covering all vehicles and
automotive equipment owned, hired, or in the custody and control of Contractor
and complying with all applicable legislation with limits not less than *
combined single limit for the death or injury of any person per accident and not
less than * for the loss or damage to property resulting from any one accident.
4. All Risk Insurance in respect of all property of Contractor, its respective
officers, agents and employees connected with the performance of the Work
against all loss or damage from whatever cause.
5. Conventional Marine Hull and Machinery Insurance including War Risks or any
vessel(s) owned, operated or chartered by the Contractor, in an amount equal to
the full value thereof. In the event of damage to or loss of such vessel(s), the
Contractor agrees to look to its insurance carrier for payment of such loss or
damage and hereby releases the Purchaser and waives any claims against the
Purchaser for the loss of such vessel(s) unless due to the negligence of
Purchaser, its agent or representatives (other than Contractor).
6. All vessels are to be entered in a Mutual Protection and Indemnity
Association with a full and unlimited entry or to have Marine Protection and
Indemnity Insurance with a limit of not less than * including coverage far
illness, injury or death of crew members (unless
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
57
covered under Workmen's Compensation Insurance), Contractual Liability Coverage,
Collision and Tower's Liability, Removal of Wreck and Debris and Third Party
Liability.
7. Excess Liability Coverage over that required in Sub-Articles 27(A)(1), (2)
and (3) with minimum limits of * for any one accident or occurrence.
8. Specialist Operations Insurance with a limit of not less than * as per
London Wording 1993 or equivalent.
9. Transit Insurance including inland, air, and Marine Cargo coverage including
War (other than on land) in an amount sufficient to cover the expected highest
value of any one shipment. Coverage to include Institute Cargo Clauses, all
risks 1.1.63, Institute War Clauses, London Malicious Damage Clause, and
Institute Strikes Riots and Civil Commotion Clauses or their equivalent.
10. Marine Cargo or equivalent is required to protect, for full cost, against
all risks of physical loss or damage to the plant, equipment and supplies to be
included in the System (other than War Risks) beginning with when each such
item is ready for shipping and ending when the submersible plant and equipment
are placed overside the cable laying vessel and when the equipment and supplies
are delivered to the cable stations, central offices, or network operation
center. The coverage continues to cover cable lying on the seabed.
11. Sea Bed or equivalent coverage (including an Old Mines and Torpedoes
Clause, including other derelict weapons of War) is required to protect, for
full cost, against all risks of physical loss or damage to the submersible plant
and equipment described in Sub-Article 27(A)(10) above. See last paragraph.
12. War Risks or equivalent coverage is required to protect against damage to,
seizure by and/or destruction of the System by means of war, piracy, takings at
sea and other warlike operations until discharge of the submersible plant and
equipment. For the purposes of this Article "discharge of the submersible plant
and equipment" shall be deemed to take place when the plant and equipment
reaches the sea bottom, as far as the submersible plant and equipment is
concerned, and when the plant is off-loaded in the respective terminal country,
as far as non-submersible plant is concerned.
13. Pollution Liability (EIL) insurance for installation operations and as
arising from the use of vessels in an amount not less than * or such higher sum
as may be required to meet any legal requirement in area of operations.
The Comprehensive General Liability Insurance required pursuant to Sub-Article
27(A)(2) above, shall include Contractual Liability Coverage which shall
specifically apply to the obligations assumed by the Contractor under the Terms
and Conditions of this Contract.
B. 1. All the foregoing insurances shall be effected with a creditworthy
insurer and shall be endorsed to provide Purchaser with at least thirty (30)
days prior written notice of cancellation or material change.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
58
2. All the foregoing insurances shall name Purchaser as an additional insured
as to operations hereunder, in which event the Contractor's insurance shall be
primary to any insurance carried by Purchaser.
3. The limits specified herein are minimum requirements and shall not be
construed in any way as limits of liability or as constituting acceptance by
Purchaser of such responsibility for financial liabilities in excess of such
limits. The Contractor shall bear all deductibles applicable to any insurance.
4. If it is judicially determined that the monetary limits of insurance
required hereunder or of any indemnity voluntarily assumed under the Terms and
Conditions of this Contact which the Contractor agrees will be supported either
by available liability insurance or voluntarily self-insured, in part or whole,
exceeds the maximum limits permitted under applicable law, it is agreed that
said insurance requirements or indemnity shall automatically be amended to
conform to the maximum monetary limits permitted under such law.
5. Contractor shall take reasonable steps to provide that any sub-contractor
engaged by it has in effect or will effect Employer's Liability, Workmen's
Compensation, Hull and Machinery and Protection and Indemnity insurances and any
other insurances required by law, together with such other insurances as the
Contractor may consider necessary.
6. If the Contractor fails to effect or keep in force any of the insurances
required under this Contract, Purchaser may effect and keep in force any such
insurances and pay such premiums as may be necessary for that purpose and from
time to time deduct the amount so paid by Purchaser from any money due or which
may become due to the Contractor hereunder or recover the same as a debt due
from the Contractor, provided that Purchaser is not in Default.
7. Each Party shall give the other prompt notification of any claim with
respect to any of the insurances to be provided hereunder, accompanied by full
details giving rise to such claim. Each Party shall afford the other all such
assistance as may be required for the preparation and negotiation of insurance
claims.
8. Contractor shall report to Purchaser as soon as practicable all accidents or
occurrences resulting in injuries to Contractor's employees or third parties, or
damage to property of third parties, arising out of our during the course of
services for Purchaser by Contractor.
C. The Contractor may organize such levels of deductibles, excesses and self-
insurance as it considers appropriate and which are within prudent industry
standards.
D. The insurance requirements of this Article 27 will remain in place with
respect to each DLS, the System or System Upgrade, as the case may be, and will
not in any way be diminished or reduced until the transfer of title and risk of
loss shall have passed to Purchaser of such DLS, System or System Upgrade, as
the case may be, even in the event of the sale of substantially all the assets
of the Contractor by way of a merger, consolidation or sale of assets.
59
ARTICLE 28 PLANT AND WORK RULES
---------- --------------------
Employees and agents of each Party shall, while on the premises of the other or
its subcontractors, comply with all plant rules and governmental regulations.
ARTICLE 29 RIGHT OF ACCESS
---------- ---------------
A. The Contractor shall, upon reasonable notice of not less than ten (10)
working days, during normal business hours and in a manner to avoid any
disruption of the work on the premises including performance of other contracts,
permit access by the Purchaser or its Quality Assurance (QA) Representative
(other than a competitor of the Contractor or any affiliate of a competitor) to
the Contractor's premises where the work will be performed, and will use its
best endeavors to secure rights of access to premises of its subcontractors
where the work will be performed, having subcontracts or orders in the amount
of, or equivalent to U.S. $125,000 or more, in accordance with the Contractor's
contractual arrangements with its subcontractors, and allow the Purchaser or its
QA Representative to:
1. audit the Contractor's quality assurance system and its application to the
Work and Upgrade Work, including manufacture, development and raw materials and
components provision;
2. inspect all parts of the Work and Upgrade Work to the extent reasonably
practicable to ensure that their quality meets the Technical Specification.
This right of access shall allow for the Purchaser and/or its QA representative
(up to a total of three (3) persons). The Purchaser shall provide the name(s),
nationality and title of each such visitor prior to the visit. The Contractor
shall not be responsible for any costs, including travel and accommodation
costs, of the Purchaser or its representatives.
B. The right of access shall also allow for the Purchaser and/or
representatives (up to a total of three (3) persons) to be aboard the vessel(s)
during installation and the route survey, provided accommodations are available.
The Contractor shall not be responsible for any costs of the Purchaser or its
representatives, except for living expenses on board the vessel which includes
one (1) daily telex or fax, all other travel and accommodation costs for the
Purchaser or its QA Representatives shall be for the account of the Purchaser.
C. Any right of access shall not be construed as creating any obligation
requiring the Contractor or its subcontractors to disclose trade secrets or
proprietary information. Further, such right of access may be conditioned on the
execution of a confidentiality and non-disclosure agreement and/or subject to
routine building or security rules, regulations or procedures.
D. Any exercise of any right of the Purchaser hereunder to inspect, audit,
visit or to serve any part of the Work or System Upgrades shall not be construed
as limiting any obligation of Contractor hereunder, including without
limitation, under Articles 1 and 10 hereof.
60
E. Contractor will have access to the System as necessary to accomplish its
responsibilities under this Contract and in order to make repairs and to make
System Upgrades. Contractor will provide reasonable notice of its need for
access and will take reasonable steps to minimize disruptions to the operation
of the System.
F. Contractor shall give the Purchaser reasonable prior written notice of each
monthly project management review meeting with respect to the status of the
construction and/or installation of the System, and Purchaser's representatives
(up to three such representatives) and the Independent Engineer shall at their
cost be permitted to attend and participate in such meetings.
ARTICLE 30 QUALITY ASSURANCE
---------- -----------------
All equipment, material and supplies provided under this Contract shall be
inspected and tested by representatives designated by the Contractor to the
extent reasonably practical to assure that the quality of the equipment,
materials and supplies being incorporated is sufficient to realize the System
Performance Requirements. The inspection and test program established for such
equipment, materials and supplies shall be consistent with commercial practices
normally employed by the Contractor in the construction of submarine cable
systems. The foregoing shall not be construed as limiting any of the
Contractor's obligations under this Contract.
ARTICLE 31 DOCUMENTATION
---------- -------------
The Contractor shall furnish to the Purchaser five copies of the standard
documentation in the English language for the System provided hereunder. Such
documentation shall be provided prior to the Acceptance testing. Additional
copies of the documentation are available at additional cost.
ARTICLE 32 TRAINING
---------- --------
The Contractor will provide, as part of the Initial Contract Price, until the
Date of Final Acceptance, any and all training, as more particularly described
in the training section of Appendix 6, necessary for the operation and
maintenance of the System.
ARTICLE 33 SETTLEMENT OF DISPUTES/ARBITRATION/LITIGATION
---------- ---------------------------------------------
A. The Parties shall endeavor to settle amicably by mutual discussions any
disputes, differences, or claims whatsoever related to this Contract.
B. Failing such amicable settlement, any controversy, claim or dispute arising
under or relating to this Contract, including the existence, validity,
interpretation, performance, termination or breach thereof, shall, if both
Parties agree in writing thereto, finally be settled by arbitration in
accordance with the International Arbitration Rules of the American Arbitration
Association ("AAA"). Unless the Parties agree to a sole arbitrator, there shall
be three (3) arbitrators, with each Party appointing one arbitrator, who
collectively will select a third. The
61
language of the arbitration shall be English. The Arbitrator will not have
authority to award punitive damages to either Party. Each Party shall bear its
own expenses, but the Parties shall share equally the fees and expenses of the
Arbitration Tribunal and the AAA. This Contract shall be enforceable, and any
arbitration award shall be final, and judgment thereon may be entered in any
court of competent jurisdiction. In any such arbitration, the decision in any
prior arbitration under this Contract shall not be deemed conclusive of the
rights as among themselves of the Parties hereunder. The arbitration shall be
held in New York, New York, U.S.A.
C. 1.If both Parties do not agree to arbitration pursuant to paragraph (B)
above, then either Party may institute suit in the Supreme Court of the State of
New York sitting in New York County or the United States District Court of the
Southern District of New York, or any appellate court from any thereof.
2.Each Party hereby irrevocably and unconditionally submits to the non-exclusive
jurisdiction of any New York State or Federal court sitting in The City of New
York, and any appellate court from any thereof, in any action or proceeding
arising out of or relating to this Contract, and each Party hereby irrevocably
and unconditionally agrees that all claims in respect of such action or
proceeding may be heard and determined in such New York State court or, to the
extent permitted by law, in such Federal court. Each Party hereby irrevocably
and unconditionally waives, to the fullest extent it may effectively do so, any
defense of an inconvenient forum to the maintenance of such action or proceeding
in any such court and any right of jurisdiction on account of the place of
residence or domicile of either Party. The Contractor hereby irrevocably and
unconditionally appoints CT Corporation System (the "New York Process Agent"),
----------------------
with an office on the date hereof at 0000 Xxxxxxxx, Xxx Xxxx, Xxx Xxxx, as its
agent to receive on behalf of the Contractor and its respective property service
of copies of the summons and complaint and any other process which may be served
in any such action or proceeding in any such New York State or Federal court and
agrees promptly to appoint a successor New York Process Agent in The City of New
York (which successor Process Agent shall accept such appointment in a writing
prior to the termination for any reason of the appointment of the initial New
York Process Agent). In any such action or proceeding in such New York State or
Federal court sitting in The City of New York, such service may be made on the
Contractor by delivering a copy of such process to the Contractor in care of the
appropriate Process Agent at such Process Agent's above address and by
depositing a copy of such process in the mails by certified or registered air
mail, addressed to the Contractor at its address referred to in Article 35 of
this Contract (such service to be effective upon such receipt by the appropriate
Process Agent and the depositing of such process in the mails as aforesaid). The
Contractor hereby irrevocably and unconditionally authorizes and directs such
Process Agent to accept such service on its behalf. As an alternate method of
service, the Contractor also irrevocably and unconditionally consents to the
service of any and all process in any such action or proceeding in such New York
State or Federal court sitting in The City of New York by mailing of copies of
such process to the Contractor, as the case may be, by certified or registered
air mail at its address referred to in Article 35 of this Contract. The
Contractor agrees that, to the fullest extent permitted by applicable law, a
final judgment in any such action or proceeding shall be conclusive and may be
enforced in other jurisdictions by suit on the judgment or in any other manner
provided by law.
62
3. WAIVER OF JURY TRIAL. EACH PARTY HERETO HEREBY WAIVES, TO THE FULLEST
--------------------
EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN
ANY LEGAL PROCEEDING DIRECTLY OR INDIRECTLY ARISING OUT OF OR RELATING TO THIS
AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY (WHETHER BASED ON CONTRACT,
TORT OR ANY OTHER THEORY). EACH PARTY HERETO (A) CERTIFIES THAT NO
REPRESENTATIVE, AGENT OR ATTORNEY OF ANY OTHER PARTY HAS REPRESENTED, EXPRESSLY
OR OTHERWISE, THAT SUCH OTHER PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK
TO ENFORCE THE FOREGOING WAIVER AND (B) ACKNOWLEDGES THAT IT AND THE OTHER
PARTIES HERETO HAVE BEEN INDUCED TO ENTER INTO THIS AGREEMENT BY, AMONG OTHER
THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS IN THIS PARAGRAPH.
D. THE OBLIGATIONS OF EACH PARTY IN RESPECT OF THIS CONTRACT DUE TO ANY PARTY
SHALL, NOTWITHSTANDING ANY JUDGMENT IN A CURRENCY (THE "JUDGMENT CURRENCY")
-----------------
OTHER THAN DOLLARS, BE DISCHARGED ONLY TO THE EXTENT THAT ON THE BUSINESS DAY
FOLLOWING RECEIPT BY SUCH PARTY OF ANY SUM ADJUDGED TO BE SO DUE IN THE JUDGMENT
CURRENCY SUCH PARTY MAY IN ACCORDANCE WITH NORMAL BANKING PROCEDURES PURCHASE
DOLLARS WITH THE JUDGMENT CURRENCY; IF THE AMOUNT OF DOLLARS SO PURCHASED IS
LESS THAN THE SUM ORIGINALLY DUE TO SUCH PARTY IN DOLLARS, EACH PARTY AGREES, AS
A SEPARATE OBLIGATION AND NOTWITHSTANDING ANY SUCH JUDGMENT, TO INDEMNIFY SUCH
PARTY AGAINST SUCH LOSS, AND IF THE AMOUNT OF DOLLARS SO PURCHASED EXCEEDS THE
SUM ORIGINALLY DUE TO ANY PARTY TO THIS CONTRACT, EACH PARTY AGREES TO REMIT TO
SUCH PARTY, SUCH EXCESS.
ARTICLE 34 APPLICABLE LAW
---------- --------------
THIS CONTRACT SHALL BE CONSTRUED AND GOVERNED IN ACCORDANCE WITH THE LAWS XX XXX
XXXXX XX XXX XXXX, XXXXXX XXXXXX, EXCLUDING ITS CONFLICTS OF LAW PROVISIONS AND
EXCLUDING THE CONVENTION FOR THE INTERNATIONAL SALE OF GOODS.
ARTICLE 35 NOTICES
---------- -------
A. Any notices, consent, approval, or other communication pursuant to this
Contract shall be in writing, in the English language, and shall be deemed to be
duly given or served on a Party if sent to the Party at the address stipulated
in Sub-Article 35(B) and if sent by any one of the following means only:
1. Sent by hand: Such communication shall be deemed to have been received on
the day of delivery provided receipt of delivery is obtained.
63
2. Sent by facsimile: Such communication shall be deemed to have been received,
under normal service conditions, twenty-four (24) hours following the time of
dispatch or on confirmation by the receiving Party, whichever is earlier.
3. Sent by registered or certified mail: Such communication shall be deemed to
have been received, under normal service conditions, on the day it was received
or on the tenth day after it was dispatched, whichever is earlier.
B. For purposes of this Article, the names, addresses and fax numbers of the
Parties are as detailed below. Any change to the name, address, and facsimile
numbers may be made at any time by giving thirty (30) days prior written notice.
Tyco Submarine Systems Ltd.
000 Xx. Xxxxxx Xxxxxx
Xxxxxxxxxx, Xxx Xxxxxx 00000
Tel: 000-000-0000
Fax: 000-000-0000
Pan American Crossing Ltd.
Wessex House
00 Xxxx Xxxxxx
Xxxxxxxx XX00
Xxxxxxx
Fax: 000-000-0000/8606
Attn: Xxxxxxx Xxxxxxxx
C. All provisions in this Contract regarding notices, consents, approvals and
other communications to and from, and other actions taken on behalf of, the
Contractor are subject to the provisions of Article 42 hereof.
ARTICLE 36 PUBLICITY AND CONFIDENTIALITY
---------- -----------------------------
A. No information relating to this Contract shall be released by either Party
to any newspaper, magazine, journal or other written, oral or visual medium
without the prior written approval of an authorized representative of the other
Party; provided that, subject to Article 20 (Safeguarding of Information and
--------
Technology) and the following Sub-Article, this Article shall not restrict
either Party from (i) responding to customary press inquiries or otherwise
making public or private statements in the normal course of business, so long as
consistent with a mutually agreed press-release and (ii) assisting in the
obtaining of financing in accordance with Sub-Article 37(C), including the
publication of a financial tombstone.
B. This Contract and any non-public information, written or oral, with respect
to this Contract, "Confidential Information", will be kept confidential and
shall not be disclosed, in whole or in part, to any person other than
affiliates, officers, directors, employees, agents or representatives of a Party
(collectively, "Representatives") who need to know such Confidential
64
Information for the purpose of negotiating and executing this Contract. Each
Party agrees to inform each of its Representatives of the non-public nature of
the Confidential Information and to direct such persons to treat such
Confidential Information in accordance with the terms of this Article. Nothing
herein shall prevent a Party from disclosing Confidential Information (a) upon
the order of any court or administrative agency, (b) upon the request or demand
of, or pursuant to any regulation of, any regulatory agency or authority, (c) to
the extent reasonably required in connection with the exercise of any remedy
hereunder, (d) to a Party's legal counsel or independent auditors, (e)
prospective lenders to the Purchaser or Purchaser's parent companies, and (f) to
any actual or proposed assignee of all or part of its rights hereunder provided
that such actual or proposed assignee agrees in writing to be bound by the
provisions of this Article.
ARTICLE 37 ASSIGNMENT; SUBCONTRACTORS
---------- --------------------------
A. Except as provided in this Article, neither Party shall assign this Contract
or any right or interest under this Contract, nor delegate any work or
obligation to be performed under this Contract ("Assignment"), without the other
Party's prior written consent which shall not be unreasonably withheld (it being
understood that it shall be deemed to be reasonable to withhold consent to the
assignment of this Contract or any rights, interest or obligations hereunder to
a competitor of Contractor or an affiliate of a competitor or uncreditworthy
party). Nothing herein shall preclude a Party from employing a subcontractor in
carrying out its obligations under this Contract. A Party's use of such
subcontractor shall not release the Party from its obligations or liability
(including warranties) under this Contract. If a proposed subcontractor of major
equipment (i.e., equipment listed on Exhibit E) is not listed on Exhibit E
hereto, Contractor shall obtain approval thereof from Purchaser, which approval
shall not be unreasonably withheld.
B. The Contractor has the right to assign all of its rights under this Contract
or to delegate all of its duties hereunder at any time without the Purchaser's
consent to any successor to substantially all the assets of the Contractor by
way of a merger, consolidation or sale of assets provided that in the case of
any assignment or delegation pursuant to this Sub-Article 37(B) such assignee
shall assume in writing all warranties, representations and obligations of
Contractor under this Contract. The Contractor shall give the Purchaser written
notice 30 days prior to the assignment.
C. The Parties acknowledge that Purchaser may finance construction of the
System on a "project finance" basis and that in connection therewith the
financing parties will require that such financing be secured by certain assets
of Purchaser (including but not limited to this Contract). The Purchaser may, in
connection with any such project financing grant a collateral assignment of the
System and/or its rights and obligations under this Contract to any such
financing parties, and in connection therewith, the Contractor will execute and
deliver a Consent, substantially in the form of Exhibit B hereto; provided that
Contractor agrees to make such changes or additions to such form as may be
reasonably requested by such financing parties, and Purchaser, and such
financing parties, may transfer in accordance with such Consent. Contractor
will also deliver an Opinion in the form of Exhibit C hereto, and a similar
opinion of * with respect to the * to Purchaser and such financing parties and
such other documents as are reasonably requested by such financing parties.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
65
D. The Purchaser has the right to assign all of its rights and delegate all of
its duties under this Contract to any other entity to whom all of Purchaser's
rights and interests in the System have been transferred. Purchaser also has
the right (i) to assign all of its rights hereunder with respect to any
particular Landing Assets to any Transferee, (ii) to assign Permits with respect
to such Landing Assets, or have Permits with respect to such Landing Assets
issued in the name of, such Transferee and (iii) to transfer such Landing Assets
or have such Landing Assets transferred directly to, such Transferee; provided
--------
that such Transferee shall execute a supplement to this Contract whereby it
becomes jointly and severally liable, together with Purchaser, for all of
Purchaser's obligations under this Contract. "Landing Assets" means, with
respect to each jurisdiction where a portion of the System is located, all or
part of such portion of the System located therein. It is understood that the
Purchaser, at its option, may assign and transfer rights with respect to Landing
Assets in different jurisdictions to different Transferees. Purchaser shall not
transfer any of its rights under this Contract or the System except in
accordance with the foregoing. Any assignment or transfer not expressly
permitted by Sub-Article 37(D) shall be of no force and effect. Any assignment
or transfer which results in any increase in costs or any loss, damage, delay or
failure of performance shall constitute a Force Majeure, and, without limiting
the applicability of Article 17 (Force Majeure), Purchaser shall be responsible
for any increase in costs resulting therefrom.
ARTICLE 38 RELATIONSHIP OF THE PARTIES
---------- ---------------------------
All work performed by a Party under this Contract shall be performed as an
independent contractor and not as an agent of the other and no persons furnished
by a Party shall be considered the employees or agents of the other. Each Party
shall be responsible for its employees' compliance with all Laws while
performing under this Contract. This Contract shall not form a joint venture or
partnership between the Parties.
ARTICLE 39 SUCCESSORS BOUND
---------- ----------------
This Contract shall be binding on the Contractor and the Purchaser and their
respective successors and permitted assigns.
ARTICLE 40 ARTICLE CAPTIONS
---------- ----------------
The captions of the Articles do not form part of this Contract and shall not
have any effect on the interpretation thereof.
ARTICLE 41 SEVERABILITY
---------- ------------
If any of the provisions of this Contract shall be invalid or unenforceable,
such invalidity or unenforceability shall not invalidate or render unenforceable
the entire Contract, but rather the entire Contract shall be construed as if not
containing the particular invalid or unenforceable provision or provisions and
the rights and obligations of the Contractor and the Purchaser shall be
construed and enforced accordingly. In the event such invalid or unenforceable
provision is an
66
essential and material element of this Contract, the Parties shall promptly
negotiate a replacement provision.
ARTICLE 42 *
---------- -----------
*
ARTICLE 43 SURVIVAL OF OBLIGATIONS
---------- -----------------------
The Parties' rights and obligations, which, by their nature would continue
beyond the termination, cancellation or expiration of this Contract, including,
but not limited to, those contained in Sub-Article 4(B) (Taxes, Levies and
Duties) and Sub-Article 4(C) (Withholding Tax), Article 18 (Intellectual
Property), Article 20 (Safeguarding of Information and Technology), Article 21
(Export Control) and Article 23 (Limitation of Liability/Indemnification) shall
survive termination, cancellation or expiration hereof. Article 10 (Warranty)
and Article 11 (Contractor Support), shall survive termination, cancellation or
expiration hereof, if and only if, this Contract is terminated by Purchaser
pursuant to Sub-Article 13(A).
ARTICLE 44 NON-WAIVER -
---------- ---------- -
A waiver of any of the terms and conditions of this Contract, or the failure of
either Party strictly to enforce any such term or condition, on one or more
occasions shall not be construed as a waiver of the same or of any other term or
condition of this Contract on any other occasion.
ARTICLE 45 LANGUAGE
---------- --------
This Contract has been executed in the English language and English will be the
controlling language for interpretation of this Contract.
ARTICLE 46 ENTIRE AGREEMENT
---------- ----------------
This Contract supersedes all prior oral or written understanding between the
Parties and constitutes the entire agreement with respect to the subject matter
herein. Any modification, amendment, waiver, approval or consent given hereunder
must be evidenced by a writing signed by authorized representatives of all
Parties.
* Material omitted and separately filed with the Commission under an
application for confidential treatment.
67
This Contract is executed in Bermuda by a duly authorized representative of the
Purchaser, and in Nassau, the Bahamas, by a duly authorized representative of
Contractor, as set forth below.
TYCO SUBMARINE SYSTEMS LTD.
By:/s/ Xxxx X. Xxxxxx
--------------------
Name: Xxxx X. Xxxxxx
Title: Director, American Region
PAN AMERICAN CROSSING LTD.
By:/s/ K. Xxxxxx Xxxxxxx
----------------------
Name: K. Xxxxxx Xxxxxxx
Title: President
