1
EXHIBIT 10.1
MODIFICATION NO. 1
TO THE CONTRACT BETWEEN
ECHOSTAR ORBITAL CORPORATION
AND
LOCKHEED XXXXXX CORPORATION
This Modification is effective the 25th day of February 2000.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Revise ARTICLE 2 "EQUIPMENT AND SERVICES TO BE FURNISHED AND PRICES
THEREFOR" to remove TBDs.
o Modify Exhibit B to EchoStar VII Spacecraft Performance Specification
Doc#8575921 Rev. A in order to remove TBDs.
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
2
1) ARTICLE 2. EQUIPMENT AND SERVICES TO BE FURNISHED AND PRICES THEREFOR
Paragraph D. Option for additional CONUS Transmit Reflector and Feed System for
Spot Beams for less than or equal to ten (10) degrees from 119 degrees X.X.,
delete the text of paragraph D in its entirety and replace it with:
D. Option for additional CONUS Transmit Reflector and Feed System for Spot
Beams for less than or equal to ten (10) degrees from 119 degrees X. X.
Buyer may exercise this option by providing Contractor authorization to
proceed, at a specific orbital location, no later than forty (40) days
after EDC. Additionally, Buyer shall have the option, exercisable in its
discretion by providing written notice to Contractor, at any time until ten
(10) months after EDC (or later if Buyer and Contractor mutually agree to
an equitable adjustment, or to the deletion of testing as necessary in
order to maintain schedule), to direct Contractor to commence integration
and test of either the baseline antenna set or this Optional CONUS Transmit
Reflector and Feed System for Spot Beams for installation on the
Spacecraft, without affecting schedule. In the event Buyer desires to
exercise this Option subsequent to the date(s) specified above, but prior
to twenty-three (23) months following EDC, then the price for the Option
and the Delivery schedule shall be subject to equitable adjustments. The
Contractor shall use reasonable care to mitigate any impacts to the price
and/or delivery schedule.
If Buyer exercises this option, Contractor shall commence phases
[CONFIDENTIAL INFORMATION OMITTED] below only following receipt of written
notice from Buyer; such notice shall be provided at least thirty (30) days
prior to the date shown in the schedule below for commencement of the
relevant phase as adjusted for any delays, directing Contractor to commence
that phase (Buyer recognizes that if it fails to provide written notice at
least thirty (30) days prior to the date shown in the schedule below for
commencement of any such phase, but subsequently elects to continue the
extra antenna procurement effort, Contractor shall be entitled to an
equitable adjustment). Buyer shall make payment to Contractor in the
amounts set forth below within thirty (30) days after the option turn on
and the commencement of each phase thereafter; provided that Contractor
submits an invoice to Buyer no later than thirty (30) days prior to the
applicable payment due date; provided further that if Contractor fails to
timely submit an invoice to Buyer, then the applicable payment shall be due
thirty (30) days after Buyer receives the relevant invoice. If Buyer does
not direct that the procurement effort continue to the next phase, no
further payments shall be due and Contractor shall not be obligated to
continue with the work in this Option.
Upon request, Contractor will provide Buyer with a schedule of work to be
completed within the two month period following option turn on. Within
forty five (45) days prior to the commencement date of each phase
thereafter as adjusted for any delays, Contractor will provide Buyer with a
schedule of work to be completed during that phase.
3
COMMENCEMENT DATE
OF EACH PHASE
(MONTHS AFTER
PHASE NO. PHASE AMOUNT AUTHORIZED TURN ON)
--------- ----- ----------------- ------------------
[CONFIDENTIAL INFORMATION OMITTED]
Paragraph E. Option for additional CONUS Transmit Reflector, Receive reflector
and Feed System for Spot Beams for more than ten (10) degrees from 119 degrees
X.X., delete the text of paragraph in its entirety and replace with:
E. Option for additional CONUS Transmit Reflector, Receive reflector and Feed
System for Spot Beams for more than ten (10) degrees from 119 degrees X.X.
Buyer may exercise this option by providing Contractor authorization to
proceed, at a specific orbital location, no later than forty (40) days
after EDC. Additionally, Buyer shall have the option, exercisable in its
discretion by providing written notice to Contractor, at any time until ten
(10) months after EDC (or later if Buyer and Contractor mutually agree to
an equitable adjustment, or to the deletion of testing as necessary in
order to maintain schedule), to direct Contractor to commence integration
and test of either the baseline antenna set or this Optional CONUS Transmit
Reflector, Receive reflector and Feed System for Spot Beams for
installation on the Spacecraft, without affecting schedule. In the event
Buyer desires to exercise this Option subsequent to the date(s) specified
above, but prior to twenty-three (23) months following EDC, then the price
for the Option and the Delivery schedule shall be subject to equitable
adjustment. The Contractor shall use reasonable care to mitigate any
impacts to the price and/or delivery schedule.
If Buyer exercises this option, Contractor shall commence phases
[CONFIDENTIAL INFORMATION OMITTED] below only following receipt of written
notice from Buyer; such notice shall be provided at least thirty (30) days
prior to the date shown in the schedule below for commencement of the
relevant phase as adjusted for any delays, directing Contractor to commence
that phase (Buyer recognizes that if it fails to provide written notice at
least thirty (30) days prior to the date shown in the schedule below for
commencement of any such phase, but subsequently elects to continue the
extra antenna procurement effort, Contractor shall be entitled to an
equitable adjustment). Buyer shall make payment to Contractor in the
amounts set forth below within thirty (30) days after the option turn on
and the commencement of each phase thereafter; provided that Contractor
submits an invoice to Buyer no later than thirty (30) days prior to the
applicable payment due date; provided further that if Contractor fails to
timely submit an invoice to Buyer, then the applicable payment shall be due
thirty (30) days after Buyer receives the relevant invoice. If Buyer does
not direct that the procurement effort continue to the next phase, no
further payments shall be due and Contractor shall not be obligated to
continue with the work in this Option.
Upon request, Contractor will provide Buyer with a schedule of work to be
completed within the two month period following option turn on. Within
forty five (45) days prior to the commencement date of each phase
thereafter as adjusted for any delays, Contractor will provide Buyer with a
schedule of work to be completed during that phase.
4
COMMENCEMENT DATE
OF EACH PHASE
(MONTHS AFTER
PHASE NO. PHASE AMOUNT AUTHORIZED TURN ON)
--------- ----- ----------------- ------------------
[CONFIDENTIAL INFORMATION OMITTED]
2) EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921
Delete EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921
in its entirety and replace with Echostar VII Spacecraft Performance
Specification Doc#8575921 Rev. A.
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL CORPORATION LOCKHEED XXXXXX CORPORATION
By: By:
------------------------------- ---------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
-------------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
5
MODIFICATION NO. 2
TO THE CONTRACT BETWEEN
ECHOSTAR ORBITAL CORPORATION
AND
LOCKHEED XXXXXX CORPORATION
This Modification is effective the 28th day of February 2000.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Modify Exhibit B to EchoStar VII Spacecraft Performance Specification
Doc#8575921 Rev. A, to incorporate the mutually agreed upon changes to
Regional Coverage EIRP for [CONFIDENTIAL INFORMATION REDACTED] as
identified in Table 4A. SPECIFIED WORST CASE EIRPS FOR CITIES (REGIONAL
COVERAGE)(120 Watt Operation Mode)
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
6
1) EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921,
Delete TABLE 4A. SPECIFIED WORST CASE EIRPS FOR CITIES (REGIONAL COVERAGE) (120
Watt Operation Mode) page 27 of 67 in its entirety and replace with TABLE 4A.
SPECIFIED WORST CASE EIRPS FOR CITIES (REGIONAL COVERAGE) (120 Watt Operation
Mode) 8575921, Rev.A, SCN: A1 dated February 28, 2000 page 27 of 67.
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL CORPORATION LOCKHEED XXXXXX CORPORATION
By: By:
------------------------------ -------------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
-------------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
7
MODIFICATION NO. 3
TO THE CONTRACT BETWEEN
ECHOSTAR ORBITAL CORPORATION
AND
LOCKHEED XXXXXX CORPORATION
This Modification is effective the 17th day of May 2000.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Modify Exhibit B the EchoStar VII Spacecraft Performance Specification
Doc#8575921 Rev. A. This modification incorporates mutually agreed upon
changes as identified in the attached Change Control Board (CCB) #290,
dated May 10, 2000.
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
8
1) EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921,
Delete EXHIBIT B ECHOSTAR VII SPACECRAFT PERFORMANCE SPECIFICATION DOC#8575921
REV. A in its entirety and replace with EXHIBIT B ECHOSTAR VII SPACECRAFT
PERFORMANCE SPECIFICATION DOC#8575921 REV. B.
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL CORPORATION LOCKHEED XXXXXX CORPORATION
By: By:
----------------------------- -----------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
---------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
9
MODIFICATION NO. 4
TO THE CONTRACT BETWEEN
ECHOSTAR ORBITAL CORPORATION
AND
LOCKHEED XXXXXX CORPORATION
This Modification is effective the 18st day of August 2000.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Revise ARTICLE 4 "PAYMENT Paragraph B. SPACECRAFT PAYMENT PLAN" to move
[CONFIDENTIAL INFORMATION OMITTED] milestone event within the "Milestone
Payment Schedule for EchoStar VII Spacecraft."
o Revise ARTICLE 4 "PAYMENT Paragraph B. SPACECRAFT PAYMENT PLAN", to
increase dollar amount for the milestone event "13 months after EDC" to
include added price for the addition of a second command uplink frequency
as identified in Change Control Board (CCB) #308, dated August 11, 2000.
o Modify Exhibit B the EchoStar VII Spacecraft Performance Specification
Doc#8575921 Rev. B. This modification incorporates mutually agreed upon
changes as identified in the attached Change Control Board (CCB) #308,
dated August 11, 2000.
10
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
1) ARTICLE 4. PAYMENT
Under Paragraph B. SPACECRAFT PAYMENT PLAN and within Milestone Payment
Schedule for EchoStar VII Spacecraft, delete Milestone Description
[CONFIDENTIAL INFORMATION OMITTED] and replace with [CONFIDENTIAL INFORMATION
OMITTED]. Additionally, delete Milestone Description [CONFIDENTIAL
INFORMATION OMITTED] and replace with [CONFIDENTIAL INFORMATION OMITTED].
2) ARTICLE 4. PAYMENT
Paragraph B. SPACECRAFT PAYMENT PLAN, revise "Amount, $" for Milestone
Description [CONFIDENTIAL INFORMATION OMITTED] from [CONFIDENTIAL INFORMATION
OMITTED] to [CONFIDENTIAL INFORMATION OMITTED].
3) EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921,
Delete EXHIBIT B ECHOSTAR VII SPACECRAFT PERFORMANCE SPECIFICATION DOC#8575921
REV. B in its entirety and replace with EXHIBIT B ECHOSTAR VII SPACECRAFT
PERFORMANCE SPECIFICATION DOC#8575921 REV. C.
11
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL CORPORATION LOCKHEED XXXXXX CORPORATION
By: By:
---------------------------- ----------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
-------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
12
MODIFICATION NO. 5
TO THE CONTRACT BETWEEN
ECHOSTAR ORBITAL CORPORATION
AND
LOCKHEED XXXXXX CORPORATION
This Modification is effective the 4th day of January 2001.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Modify Exhibit B the EchoStar VII Spacecraft Performance Specification
Doc#8575921 Rev. C. This modification incorporates mutually agreed upon
changes as identified in the attached Change Control Board (CCB) Items No.
334 and No. 335, dated 12/15/00.
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
1) EXHIBIT B EchoStar VII Spacecraft Performance Specification Doc#8575921
Delete EXHIBIT B ECHOSTAR VII SPACECRAFT PERFORMANCE SPECIFICATION DOC#8575921
REV. C in its entirety and replace with EXHIBIT B ECHOSTAR VII SPACECRAFT
PERFORMANCE SPECIFICATION DOC#8575921 REV. D.
13
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL CORPORATION LOCKHEED XXXXXX CORPORATION
By: By:
------------------------------- ----------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
---------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
14
MODIFICATION NO. 6
TO THE SATELLITE CONTRACT
(ECHOSTAR VII - 119 DEGREES WEST LONGITUDE)
BETWEEN
LOCKHEED XXXXXX CORPORATION
AND
ECHOSTAR ORBITAL CORPORATION
DATED JANUARY 27, 2000
This Modification is effective the 1st day of February 2001.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") desires to procure certain risk
management services for the Satellite from Lockheed Xxxxxx Corporation
("Contractor");
WHEREAS, Contractor is willing to provide such risk management services for the
Satellite, and
WHEREAS, Xxxxx and Contractor therefore mutually agree to modify the subject
Contract to:
o Revise ARTICLE 2. EQUIPMENT AND SERVICES TO BE FURNISHED AND PRICES
THEREFOR
o Revise ARTICLE 3. DELIVERY SCHEDULE
o Revise ARTICLE 4. PAYMENT
o Revise ARTICLE 8. TITLE AND ASSUMPTION OF RISK
o Revise ARTICLE 13. INDEMNIFICATION
o Revise ARTICLE 17. TERMINATION FOR DEFAULT
o Revise ARTICLE 32. SURVIVAL
o Revise ARTICLE 33. INSURANCE
15
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
1. ARTICLE 2. EQUIPMENT AND SERVICES TO BE FURNISHED AND PRICES THEREFOR
a. Add a new Item 7 to Paragraph A, as follows:
Item Quantity Description Total Price
---- -------- ----------- -----------
7. 1 Lot Risk Management Services *
b. Replace existing subparagraph (ii) of Paragraph A with the following:
(ii) Does not include the price of Optional Items or Risk Management
Services
c. Add the following immediately after subparagraph (ii) of Paragraph A:
[CONFIDENTIAL INFORMATION OMITTED]
d. Add a new Paragraph H, as follows:
H. Contractor shall perform the risk management services described
in ARTICLE 33. INSURANCE.
2. ARTICLE 3. DELIVERY SCHEDULE
Add new Item in Paragraph B, as follows:
Item Description Delivery Date
---- ----------- -------------
7. Risk Management Services As provided in ARTICLE
33. INSURANCE.
3. ARTICLE 4. PAYMENT
Add a new Paragraph G, as follows:
X. Xxxxx shall pay the premiums for all insurance procured by Contractor
under ARTICLE 33. INSURANCE to Contractor in installments
[CONFIDENTIAL INFORMATION OMITTED] days prior to the relevant due date
for payment of the insurers; provided that, in the event that Buyer
fails to pay any amount when due to Contractor under this Paragraph G,
then Buyer shall be responsible for
16
the payment of any corresponding late fees or penalties incurred by
Contractor under the relevant insurance policy. Contractor shall use
reasonable due diligence to assure an invoice is provided to Buyer on
or about the same day Contractor receives the corresponding invoice
from Contractor's insurance broker. Notwithstanding the above, Buyer
shall make payments to Contractor at least [CONFIDENTIAL INFORMATION
OMITTED] days prior to the due date of the corresponding premium
payment to Contractor's broker.
4. ARTICLE 8. TITLE AND ASSUMPTION OF RISK
Replace the existing Paragraph C in its entirety with the following:
C. EXCEPT WITH RESPECT TO WILLFUL MISCONDUCT OR GROSS NEGLIGENCE BY
CONTRACTOR, UPON AND AFTER LAUNCH OF THE LAUNCH VEHICLE FOR THE
SPACECRAFT, Contractor's sole financial risk, and THE sole and
exclusive remedies OF buyer, with respect to THE USE OR PERFORMANCE OF
THE SPACECRaFT, shall be as set forth in ArticleS 1(Paragraph C), 6,
13, 14, 15, 21 and 33.
Add a new Paragraph D, as follows:
D. In the event that Contractor places (as defined in Paragraph D of
ARTICLE 33. INSURANCE) insurance coverage under ARTICLE 33. INSURANCE,
then notwithstanding Paragraph A (1) of this ARTICLE, risk of loss or
damage to the Spacecraft shall remain with Contractor for
[CONFIDENTIAL INFORMATION OMITTED] and shall pass to Buyer upon the
expiration thereof.
5. ARTICLE 13. INDEMNIFICATION
Replace the existing Paragraph B in its entirety with the following:
B. Other than as provided in ARTICLES 1(Paragraph C), 6, 13, 14, 15, 21
and 33 upon and after Launch of the launch vehicle for the Spacecraft,
Contractor shall not be liable to Buyer, customers of Buyer or their
customers for any damages resulting from: (i) any loss or destruction
of the Spacecraft; or (ii) failure of the Spacecraft or its subsystems
to operate satisfactorily, except any such liabilities, losses and
damages that are caused by the gross negligence or willful misconduct
of Contractor. Xxxxx also agrees to cause its insurers to waive all
right of subrogation against Contractor and its officers, agents,
servants, subsidiaries and employees, subject to terms and conditions
as are then customarily available regarding such waivers.
17
6. ARTICLE 17. TERMINATION FOR DEFAULT
Replace the existing Paragraph E in its entirety with the following:
E. Absent gross negligence or willful misconduct, the remedies set forth
in this ARTICLE, and ARTICLES 1 (Paragraph C), 6, 13, 14, 15, 21, 30
and 33 shall be the sole recourse to which Buyer is entitled, under
paragraph 1 or paragraph 2 above, in the event of Contractor's
default, and Contractor shall have no liability for special, indirect,
incidental or consequential damages for lost profits or lost revenues.
7. ARTICLE 32. SURVIVAL
Replace the existing ARTICLE 32. SURVIVAL in its entirety with the
following:
The following ARTICLES shall survive the completion, expiration or
termination of this Contract: ARTICLE 11. RIGHTS IN DATA; ARTICLE 12.
PUBLIC RELEASE OF INFORMATION; ARTICLE 13. INDEMNIFICATION; ARTICLE 14.
PATENT INDEMNITY; ARTICLE 15. INDEMNIFICATION FOR TAXES; ARTICLE 21.
WARRANTY; ARTICLE 22. ARBITRATION; ARTICLE 23. APPLICABLE LAW; ARTICLE 25.
DISCLOSURE AND USE OF INFORMATION BY THE PARTIES; ARTICLE 27. PERMITS AND
LICENSES; ARTICLE 28. LIMITATION OF LIABILITY; ARTICLE 33. INSURANCE;
ARTICLE 34. INTERPARTY WAIVER OF LIABILITY.
8. ARTICLE 33. INSURANCE
[CONFIDENTIAL INFORMATION OMITTED]
9. MISCELLANEOUS
Except as expressly modified herein, the Contract shall remain in full
force and effect in accordance with its terms and conditions. All capitalized
terms not defined herein shall have the meaning ascribed to them in the
Contract.
18
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL LOCKHEED XXXXXX
CORPORATION CORPORATION
By: By:
------------------------------ -------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
--------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
19
MODIFICATION NO. 7
TO THE SATELLITE CONTRACT
(ECHOSTAR VII - 119 DEGREES WEST LONGITUDE)
BETWEEN
LOCKHEED XXXXXX CORPORATION
AND
ECHOSTAR ORBITAL CORPORATION
DATED JANUARY 27, 2000
This Modification is effective the 26th day of June 2001.
WITNESS THAT:
WHEREAS, EchoStar Orbital Corporation ("Buyer") and Lockheed Xxxxxx Corporation
("Contractor"), mutually agree to modify the subject Contract to:
o Modify Article 4.B.1. Spacecraft Payment Plan.
NOW THEREFORE, in consideration of the mutual covenants and conditions contained
herein, Buyer and Contractor agree to modify the Contract as follows:
1.) ARTICLE 4. B.1. SPACECRAFT PAYMENT PLAN
a. Replace all references to[CONFIDENTIAL INFORMATION REDACTED] and
[CONFIDENTIAL INFORMATION REDACTED] for Months after EDC 13, 15 and
17, under the table titled Milestone Payment Schedule for EchoStar
VII, [CONFIDENTIAL INFORMATION REDACTED].
b. Replace Milestone Description for Months after EDC 16 in its entirety
with the following: [CONFIDENTIAL INFORMATION REDACTED].
20
IN WITNESS WHEREOF, the parties hereto have executed this Contract Amendment.
ECHOSTAR ORBITAL LOCKHEED XXXXXX
CORPORATION CORPORATION
By: By:
---------------------------- --------------------------------
Xxxxx X. Xxxxxxxxx Xxxxxx XxXxxxx
Senior Vice President and Contracts Manager
General Counsel
EchoStar Communications Corporation hereby guarantees all of the obligations and
duties of EchoStar Orbital Corporation under the Contract to which this
guarantee is attached.
ECHOSTAR COMMUNICATIONS
CORPORATION
By:
---------------------------
Xxxxx X. Xxxxxxxxx
Senior Vice President and
General Counsel
