EXHIBIT 10.3
LEASE AGREEMENT
BASIC LEASE INFORMATION
Date: November 11, 1997
Landlord: OMB Development I, L.L.C., an
Arizona limited liability company
Tenant: Radyne Corp., a New York corporation
Premises (Section 1.1): The building to be constructed on the
property by Landlord pursuant to this
Lease, containing approximately 75,000
square feet (more or less) of building
area
Property (Section 1.1): Lots 1 and 2 of Southbank 7 and 8 as shown
in Exhibit "A", containing approximately
208,000 square feet (more or less),
located in Phoenix, Arizona
Parking Spaces (Section 1.1): Two hundred ninety-five (295) exclusive
spaces for cars
Term (Section 2.1): Ten (10) years
Extension Terms (Section 2.4): Two (2) five (5) year renewal options
Commencement Date (Section 2.1): As defined in Section 2.1
Expiration Date (Section 2.1): As defined in Section 2.1
Base Rent (Section 4.1 (a)): $538,728 per year ($44,894 per month), as
increased annually pursuant to Section 4.2
Tenant Improvement Charge As defined in Section 2.2
(Section 2.2):
Tenant's Percentage Share
(Section 4.1(b)): 100%
Security Deposit (Section 2.1): $50,000.00
Rent Payment Address (Section 4.7): 0000 X. Xxxxxxxxxx Xxxxx
Xxxxxxxxxx, Xxxxxxx 00000
Permitted Use of the Premises Design, engineering and assembly of
satellite (Section 5.1): modems, frequency
converters and ancillary products and
related office uses
Liability Insurance (Section 9.3
and 9.8): $2,000,000
- i -
Landlord's Address (Section 18.1): 0000 X. Xxxxxxxxxx Xxxxx
Xxxxxxxxxx, Xxxxxxx 00000
Tenant's Address (Section 18.1): Radyne Corp., at the address of the
Premises.
Real Estate Brokers (Section 19.5): CB Commercial Real Estate
Exhibit "A" - Plan (s) Outlining the Premises and the Property
Exhibit "B" - Work Letter
Exhibit "C" - Memorandum Confirming Term
Exhibit "D" - Subordination, Non-Disturbance and Attornment Agreement
Exhibit "E" - Estoppel Certificate
The foregoing Basic Lease Information is incorporated in and made a
part of the Lease to which it is attached. If there is any conflict between the
Basic Lease Information and the Lease, the Basic Lease Information shall
control.
OMB DEVELOPMENT I, L.L.C, RADYNE CORP.,
an Arizona limited liability company a New York corporation
By: /s/ Xxxxxx X. Xxxxxxx By: /s/ R.C. Fitting
------------------------- ------------------
Its: Manager Its: President
- ii -
TABLE OF CONTENTS
ARTICLE PAGE
ARTICLE 1 Premises...................................................1
1.1 Lease of Premises..........................................1
ARTICLE 2 Term.......................................................1
2.1 Term of Lease..............................................1
2.2 Landlord's Work............................................2
2.3 Adjustment of Commencement Date............................2
2.4 Extension Option...........................................2
2.5 Holding Over...............................................3
2.6 Lease Year.................................................3
ARTICLE 3 Security Deposit...........................................3
3.1 Security Deposit...........................................3
3.2 Application of Security Deposit............................3
ARTICLE 4 Rent.......................................................4
4.1 Base Rent and Additional Rent..............................4
4.2 Base Rent Increase.........................................4
4.3 Late Payment...............................................4
4.4 Taxes Payable by Tenant....................................5
4.5 Rent Payable Address.......................................5
ARTICLE 5 Use of Premises............................................6
5.1 Permitted Use..............................................6
5.2 Rules and Regulations......................................6
ARTICLE 6 Utilities and Services ....................................6
6.1 Tenant's Responsibilities..................................6
6.2 Abatement of Rent When Tenant Is Prevented
From Using Premises........................................7
ARTICLE 7 Maintenance and Repairs....................................8
7.1 Quality of Construction - Standard for
Maintenance, Repairs and Operations........................8
7.2 Obligations of Landlord....................................8
7.3 Obligations of Tenant......................................9
- iii -
ARTICLE PAGE
ARTICLE 8 Alterations by Tenant......................................10
8.1 No Alterations by Tenant...................................10
8.2 Landlord's Property........................................11
ARTICLE 9 Indemnification and Insurance..............................12
9.1 Landlord's Indemnification.................................12
9.2 Tenant's Indemnification...................................12
9.3 Tenant's Liability Insurance...............................12
9.4 Worker's Compensation Insurance............................13
9.5 Property Insurance.........................................13
9.6 General Requirements.......................................13
9.7 Waiver of Subrogation......................................14
9.8 Landlord's Liability Insurance.............................14
9.9 Exculpation of Members.....................................14
ARTICLE 10 Property Taxes.............................................15
10.1 Property Taxes.............................................15
ARTICLE 11 Compliance With Legal Requirements.........................16
11.1 Comply With Law............................................16
ARTICLE 12 Assignment or Sublease.....................................16
12.1 Prohibition................................................16
12.2 Landlord's Consent or Termination..........................17
12.3 Completion.................................................17
12.4 Tenant Not Released........................................17
ARTICLE 13 Entry by Landlord..........................................18
13.1 Entry......................................................18
ARTICLE 14 Event of Default and Remedies..............................18
14.1 Default by Tenant..........................................18
14.2 Termination................................................19
14.3 Continuation...............................................20
14.4 Remedies Cumulative........................................20
14.5 Tenant's Primary Duty......................................20
14.6 Abandoned Property.........................................20
14.7 Landlord Default...........................................21
- iv -
ARTICLE PAGE
ARTICLE 15 Damage or Destruction......................................21
15.1 Restoration................................................21
15.2 Termination of Lease.......................................21
ARTICLE 16 Eminent Domain.............................................22
16.1 Condemnation...............................................22
16.2 Award......................................................22
16.3 Definition of Taking.......................................23
ARTICLE 17 Subordination and Sale.....................................23
17.1 Subordination..............................................23
17.2 Sale of Property...........................................24
ARTICLE 18 Estoppel Certificate.......................................24
18.1 Required Certificate.......................................24
ARTICLE 19 Notices....................................................25
19.1 Method.....................................................25
ARTICLE 20 Miscellaneous..............................................25
20.1 General....................................................25
20.2 No Waiver..................................................25
20.3 Attorney's Fees............................................26
20.4 Exhibits...................................................26
20.5 Brokers....................................................26
20.6 Entire Agreement...........................................26
20.7 Duty to Act Reasonably.....................................26
20.8 Days.......................................................27
20.9 Counter Parts..............................................27
20.10 Arbitration................................................27
ARTICLE 21 Hazardous Materials........................................27
21.1 Definition of Hazardous Materials..........................27
21.2 Definition of Environmental Requirements...................27
21.3 Prohibited Activities......................................28
21.4 Notice of Violations.......................................28
21.5 Tenant Indemnification.....................................28
21.6 Landlord Indemnification...................................29
- v -
ARTICLE PAGE
21.7 Permitted Activities.......................................29
ARTICLE 22 Fair Market Rental Rate....................................29
22.1 Determination of Fair Market Rental Rate...................29
ARTICLE 23 Guaranty...................................................32
23.1 Guaranty...................................................32
23.2 Authorization..............................................33
23.3 Waiver.....................................................33
Exhibit A - Plan (s) Outlining the Property
Exhibit B - Work Letter
Exhibit C - Memorandum Confirming Term
Exhibit D - Subordination, Non-Disturbance and Attornment Agreement
Exhibit E - Estoppel Certificate
- vi -
LEASE AGREEMENT
THIS LEASE AGREEMENT is made as of November 11, 1997, by and between OMB
DEVELOPMENT I, L.L.C., an Arizona limited liability company ("Landlord") and
RADYNE CORP., a New York corporation ("Tenant").
WITNESSETH:
ARTICLE 1
PREMISES
1.1 LEASE OF PREMISES. Landlord hereby leases to Tenant, and Tenant
hereby leases from Landlord, for the term and subject to the covenants
hereinafter set forth, to all of which Landlord and Tenant hereby agree, the
space in the building specified in the BASIC LEASE INFORMATION ("Premises"), on
the real property specified in the BASIC LEASE INFORMATION ("Property"), as
shown on the plan (s) attached hereto as Exhibit "A" and by this reference
incorporated herein. The Premises shall have located thereon two hundred
ninety-five (295) exclusive parking spaces for cars. Landlord and Tenant agree
that, for purposes of this Lease, the Premises and the Property, respectively,
each contains the number of square feet specified in the BASIC LEASE
INFORMATION, absent manifest error. Tenant shall be granted access to the
Premises, and the parking area twenty-four (24) hours per day, seven (7) days
per week, every day of the year.
ARTICLE 2
TERM
2.1 TERM OF LEASE. The term of this Lease shall be the term specified
in the BASIC LEASE INFORMATION, which shall commence on the date that Landlord
has (a) Substantially Completed Landlord's Work as defined in the Work Letter
attached hereto as Exhibit "B" and by this reference incorporated herein ("Work
Letter"); and (b) delivered possession of the Premises to Tenant ("Commencement
Date"); and, unless sooner terminated as hereinafter provided, this Lease shall
end on the date that is ten (10) years after the Commencement Date ("Expiration
Date"). The Commencement Date and the Expiration Date shall be adjusted pursuant
to Section 2.3 of this Lease. Notwithstanding the foregoing, if Landlord has not
Substantially Completed Landlord's Work and delivered possession of the Premises
to Tenant by June 1, 1998 ("Initial Completion Date"), Landlord shall pay to
Tenant on the actual Commencement Date an amount equal to the product of (i) One
Thousand Five Hundred and 00/100 Dollars ($1,500.00), multiplied by (ii) the
number of days following the Initial Completion Date to the date Landlord has
Substantially Completed Landlord's Work. In addition, if Landlord has not
Substantially Completed Landlord's Work by the date that is twelve (12) months
after the date of this Lease ("Outside Completion Date"), Tenant shall have the
right to terminate this Lease. The Initial Completion Date and the Outside
Completion Date shall be extended by one (1) business day for each business day
of delay in the Substantial Completion of the Premises that is caused by any
Force Majeure Delay or Tenant Delay (which terms are defined in the Work
Letter).
2.2 LANDLORD'S WORK. Landlord shall construct, and install in the
Premises, the building and improvements to be constructed and installed by
Landlord pursuant to the Work Letter. The terms Substantial Completion and
Landlord's Work shall have the meanings assigned to them in the Work Letter.
Landlord shall deliver possession of the Premises to Tenant on the date of
Substantial Completion of Landlord's Work, and Tenant shall accept such delivery
of the Premises, subject only to "punch-list" items
- 2 -
(minor details of construction, mechanical adjustments or decorations which do
not materially interfere with the Tenant's use of the Premises). Landlord and
Tenant acknowledge that the Landlord's Work includes the Tenant Improvements,
which has the meaning assigned to it in the Work Letter. Landlord shall
construct and install in the Premises the Tenant Improvements and shall pay the
first One Million and 00/100 Dollars ($1,000,000.00) of the cost of the Tenant
Improvements. In the event that the Tenant Improvements cost less than One
Million and 00/100 Dollars ($1,000,000.00), Landlord shall pay to Tenant on the
actual Commencement Date an amount equal to the difference between (i) One
Million and 00/100 Dollars ($1,000,000.00), less (ii) the actual cost of the
Tenant Improvements. In the event that the Tenant Improvements exceed the sum of
One Million and 00/100 Dollars ($1,000,000.00), Tenant shall pay to Landlord as
additional rent an amount equal to (i) the difference between (a) the actual
cost of the Tenant Improvements and (b) One Million and 00/100 Dollars
($1,000,000.00), multiplied by (ii) .12 ("Annual Tenant Improvement Charge").
2.3 ADJUSTMENT OF COMMENCEMENT DATE. If the Commencement Date as
determined in accordance with Section 2.1 would not be the first day on the
month and the Expiration Date would not be the last day of the month, then the
actual Commencement Date shall be the first day of the next calendar month
following the date so determined and the actual Expiration Date shall be the
last day of the appropriate calendar month so the term of this Lease shall be
the full term specified in the BASIC LEASE INFORMATION. The period of the
fractional month between the date as determined in Section 2.1 and the actual
Commencement Date as determined in this Section 2.3 shall be on and subject to
all the covenants in this Lease and, on the date as determined in Section 2.1,
Tenant shall pay to Landlord, as additional rent, the monthly Base Rent (based
on the first month for which the Base Rent is to be paid) and all additional
rent payable under Section 4.1 hereof, calculated on a per diem basis, for such
period. Landlord and Tenant each shall, promptly after the actual Commencement
Date and the actual Expiration Date have been determined, execute and deliver to
the other a Memorandum Confirming Term in the form of Exhibit "C" attached
hereto and by this reference incorporated herein that sets forth the actual
Commencement Date and the actual Expiration Date for this Lease, but the term of
this Lease shall commence and end in accordance with this Lease whether or not
Memorandum Confirming Term is executed.
2.4 EXTENSION OPTION. Provided Tenant is not otherwise in default
under the terms of this Lease, Tenant shall have the option to renew this Lease
for two (2) consecutive terms of five (5) years each, by delivering notice to
Landlord of Tenant's option to extend at least nine (9) months, prior to the end
of the current term of this Lease, or any extension thereof. If Tenant fails to
timely deliver to Landlord notice of Tenant's option to extend, then Tenant
shall have waived its option to renew, and Tenant shall have no further right to
extend the term of this Lease. If Tenant exercises its right to extend, the term
of this Lease shall be extended for the applicable five (5) year periods and
Tenant shall continue to lease the Premises on all of the terms and conditions
of this Lease, except that: (a) the Base Rent payable by Tenant during the
renewal term(s) shall be the greater of (i) the Fair Market Rental Rate, as
defined in Article 22 hereof; or (ii) the Base Rent in effect at the expiration
of the original term of this Lease, or any extension thereof,
- 3 -
whichever is applicable; and (b) after the renewal terms, Tenant shall have no
further renewal options under this Lease. Notwithstanding the foregoing, if an
Event of Default (as hereinafter defined) by Tenant occurs at any time from the
date Tenant gives Landlord notice of its option to extend up to and including
the first day of a renewal term, Landlord shall have the option of terminating
the Lease on the Expiration Date provided in the BASIC LEASE INFORMATION. In
such case, Tenant shall not be entitled to exercise its extension option.
2.5 HOLDING OVER. If Tenant holds possession of the Premises after the
expiration of the term of this Lease, or after expiration of the renewal terms
of this Lease if Tenant exercises its option to renew pursuant to Section 2.4
hereof, Tenant shall become a tenant from month to month under this Lease, but
the Base Rent during such month to month tenancy shall be equal to one hundred
fifty percent (150%) of the Base Rent in effect at the expiration of the term of
this Lease. Landlord and Tenant each shall have the right to terminate such
month to month tenancy by giving thirty (30) days' written notice of termination
to the other at any time. Receipt of any rent or any other act in apparent
affirmance of the tenancy provided for this Section 2.5 shall not operate as a
waiver of the right to terminate this Lease for breach of any terms, covenants
or obligations herein on Tenant's part to be performed.
2.6 LEASE YEAR. As used in this Lease, "Lease Year" shall mean each
period of twelve (12) months from the Commencement Date (as adjusted in
accordance with Section 2.3 hereof) during the term of this Lease.
ARTICLE 3
LETTER OF CREDIT
3.1 LETTER OF CREDIT. Tenant shall obtain and deposit with Landlord an
irrevocable letter of credit in the amount of Fifty Thousand and 00/100 Dollars
($50,000.00) ("Letter of Credit"), as partial security for Tenant's full and
faithful performance of each and every term, condition, covenant and provision
of this Lease. The Letter of Credit shall be issued by a bank qualified to do
and doing business in the state where the Premises are located and shall be in a
form acceptable to Landlord. The Letter of Credit shall provide that in the
event Tenant defaults in the performance of any term, condition, covenant or
provision hereof, Landlord may draw upon the whole or any part of the Letter of
Credit for the curing of any default or to compensate Landlord for any loss or
damage that Landlord may suffer because of Tenant's default. In no event shall
Tenant use such Letter of Credit as payment for rent or any other sum payable
under this Lease and any attempted use by Tenant of such Letter of Credit shall
constitute a material breach of this Lease.
3.2 APPLICATION OF LETTER OF CREDIT. Any use or application of the
Letter of Credit by Landlord shall be an addition to, and not substitution of or
as an alternative to, any other rights or remedies Landlord may have at law or
under this Lease, shall not prevent Landlord from pursuing its other rights and
remedies hereunder or at law or equity, and shall not prevent Landlord from
recovering damages in case of Tenant's default(s) in excess of the amount of the
Letter of Credit drawn upon. In no event shall the Letter of
- 4 -
Credit be construed as a liquidation of the damages by the parties. If Landlord
draws upon any portion of the Letter of Credit, Landlord shall notify Tenant, in
writing, of the alleged default under this Lease and the amount of the Letter of
Credit drawn upon by Landlord. Not later than ten (10) days after such notice to
Tenant, Tenant shall obtain and deposit with Landlord a replacement Letter of
Credit in an amount equal to the amount drawn by Landlord on the initial Letter
of Credit, and Tenant's failure to do so shall be a material breach of this
Lease.
ARTICLE 4
RENT
4.1 BASE RENT AND ADDITIONAL RENT. Tenant shall pay to Landlord,
without offset of deduction of any nature whatsoever except as expressly set
forth in this Lease, the following amounts as rent for the Premises:
(a) During the term of this Lease, Tenant shall pay to Landlord,
as base monthly rent, the amount of monthly Base Rent
specified in the BASIC LEASE INFORMATION, as increased
annually pursuant to Section 4.2 hereof.
(b) During the term of this Lease, Tenant shall pay to Landlord as
additional rent:
i. Tenant's Percentage Share specified in the BASIC LEASE
INFORMATION of any Property Taxes (as hereinafter
defined) paid by Landlord;
ii. Tenant's Percentage Share specified in the BASIC LEASE
INFORMATION of any Insurance Costs (as hereinafter
defined) paid by Landlord; and
iii. Annual Tenant Improvement Charge.
(c) Throughout the term of this Lease, Tenant shall pay, as
additional rent, all other amounts of money and charges
required to be paid by Tenant under this Lease, whether or not
such amounts of money or charges are designated "additional
rent". As used in this Lease, "rent" shall mean and include
all Base Rent and additional rent payable by Tenant in
accordance with this Lease.
4.2 BASE RENT INCREASES. The annual Base Rent shall be adjusted on the
first anniversary date of the Commencement Date (as adjusted pursuant to Section
2.3), and on each successive anniversary date thereof during the term of this
Lease, including the renewal terms, if any (except for the first year of the
renewal term, if any, in which case the Base Rent shall be adjusted in
accordance with Section 2.4 hereof), to an amount equal to one hundred three
percent (103%) of the annual Base Rent in effect during the immediately
preceding year.
4.3 ADDITIONAL RENT PROCEDURES. The additional rent payable by Tenant
pursuant to Section 3.1(b) hereof shall be paid in accordance with the following
procedures:
(a) Within ten (10) days of receipt of its Property Tax bills and
within ten (10) days of receipt of notification of its Insurance
Costs, Landlord shall
- 5 -
provide Tenant a copy of the Property Tax bills and Insurance
Costs for the Property.
(b) Tenant shall pay all Property Taxes and Insurance Costs at least
ten (10) days prior to the date such Property Taxes and Insurance
Costs become delinquent. Tenant shall promptly deliver to
Landlord evidence that the Property Taxes and Insurance Costs
have been paid. Tenant shall pay such Property Taxes and
Insurance Costs commencing with the Commencement Date (as
adjusted pursuant to Section 2.3) and throughout the term of the
Lease and the renewal terms, if any.
(c) If Tenant fails to timely pay all Property Taxes and Insurance
Costs, or fails to furnish Landlord with written evidence of the
payment of the Property Taxes and Insurance Costs, Landlord shall
have the right to pay the Property Taxes and Insurance Costs and
all Property Taxes and Insurance Costs paid by Landlord shall be
payable by Tenant as additional rent upon demand. Tenant shall
pay to Landlord, immediately upon demand, all costs incurred by
Landlord as a result of Tenant's failure to timely pay all
Property Taxes and Insurance Costs. If requested by any lender to
whom Landlord has granted a security interest in the Property, or
in the Event of Default by Tenant relative to the payment of Base
Rent or any additional monthly rent more than once in any
consecutive twelve (12) month period, Tenant shall pay to
Landlord a sum equal to one-twelfth (1/12) of the annual Property
Taxes and Insurance Costs payable by Tenant under this Lease.
(d) Tenant shall be entitled to any refund, credit or adjustment to
which Landlord is entitled.
(e) If the term of this Lease ends on a day other than the last day
of a calendar year, the amounts payable by Tenant under Section
4.1(b) hereof applicable to the calendar year in which such term
ends shall be prorated according to the ratio that the number of
days during the term of this Lease in such calendar year bears to
three hundred sixty-five (365). Termination of this Lease shall
not affect the obligations of Landlord and Tenant pursuant to
Section this 4.3 hereof to be performed after such termination.
(f) Tenant shall have the right to contest the Property Taxes, at
Tenant's cost and expense. Upon final determination of any
contest relating to the Property Taxes, Tenant shall immediately
reimburse Landlord for all Property Taxes.
4.4 LATE PAYMENT. Tenant acknowledges that the late payment by Tenant
of any monthly installment of Base Rent or additional monthly rent will cause
Landlord to incur costs and expenses, the exact amount of which is extremely
difficult and impractical to fix. Such costs and expenses will include
administration and collection costs and processing and accounting expenses.
Therefore, if any monthly installment of Base Rent or additional monthly rent is
not received by Landlord within ten (10) days after such
- 6 -
installment is due, Tenant shall immediately pay to Landlord, in addition to
such rent, a late charge equal to five percent (5%) of such delinquent
installment. Landlord and Tenant agree that such late charge represents a
reasonable estimate of such costs and expenses and is fair reimbursement to
Landlord. In no event shall such late charge be deemed to grant Tenant a grace
period or extension of time within which to pay any monthly rent or prevent
Landlord from exercising any right or enforcing any remedy available to Landlord
upon Tenant's failure to pay each installment of monthly rent due under this
Lease when due, including the right to terminate this Lease and recover all
damages from Tenant.
4.5 TAXES PAYABLE BY TENANT. Tenant shall reimburse Landlord upon
demand for all taxes, assessments, excises, levies, fees and charges, including
all payments related to the cost of providing facilities or services, whether or
not now customary or within the contemplation of Landlord and Tenant, that are
payable by Landlord and levied, assessed, charged, confirmed or imposed by any
public or government authority upon, or measured by, or reasonably attributable
to (a) the cost or value of Tenant's equipment, furniture, fixtures and other
personal property located in the Premises or the cost of value of any
improvements made in or to the Premises by or for Tenant, regardless of whether
title to such improvements is vested in Tenant or Landlord, (b) any rent, taxes
and insurance payable under this Lease, including any gross income tax or excise
tax levied by any public or government authority with respect to the receipt of
any such rent, taxes and insurance, (c) possession, leasing, operation,
management, maintenance, alteration, repair, use or occupancy by Tenant of the
Premises, or (d) this transaction or any document to which Tenant is a party
creating or transferring an interest or an estate in the Premises. Such taxes,
assessments, excises, levies, fees and charges shall not include net income
(measured by the income of Landlord from all sources or from sources other than
solely rent) or franchise taxes of Landlord. All taxes, assessments, excises,
levies, fees and charges payable by Tenant under this Section 4.5 shall be
deemed to be, and shall be paid as, additional rent. Tenant shall pay directly,
prior to delinquency, any personal property taxes assessed with respect to
Tenant's trade fixtures and personal property.
4.6 RENT PAYMENT ADDRESS. Tenant shall pay all Base Rent under Section
4.1 hereof to Landlord, in advance, on or before the first day of each and every
calendar month during the term of this Lease. Tenant shall pay all additional
rent under Section 4.1 hereof to Landlord on or before the date it is due.
Tenant shall pay all rent to Landlord when due without notice, demand,
deduction, abatement or offset, except as expressly provided herein, in lawful
money of the United States of America, at the address for the payment of rent
specified in the BASIC LEASE INFORMATION, or to such other person or at such
other place as Landlord may from time to time designate in writing.
4.7 PROPERTY TAXES. For purposes of this Lease, "Property Taxes" shall
mean taxes, assessments, excises, levies, fees and charges (and any tax,
assessment, excise, levy, fee or charge levied wholly or partly in lieu thereof
or as a substitute therefor or as an addition thereto) of every kind and
description, general or special, ordinary or extraordinary, foreseen or
unforeseen, secured or unsecured, whether or not now customary or within the
contemplation of Landlord and Tenant, that are levied, assessed,
- 7 -
charged, confirmed or imposed by any public or government authority on or
against, or otherwise with respect to, the Property or any part thereof or any
personal property used in connection with the Property, which are attributable
to the Property during the term of this Lease (collectively, the "Property
Taxes"). Property Taxes shall not include any of the following:
(i) Any state, federal, personal or corporate net income
taxes (measured by the income of Landlord from all sources or from
sources other than solely rent);
(ii) Any estate or inheritance taxes; and
(iii) Any franchise taxes.
4.8 INSURANCE COSTS. For purposes of this Lease, "Insurance Costs"
shall mean all premiums and other charges for all property, earthquake, flood,
loss of rental income, business interruption, liability and other insurance
relating to the Property carried by Landlord, including the insurance required
under Section 9.5 hereof.
ARTICLE 5
USE OF THE PREMISES
5.1 PERMITTED USE. The Premises shall be used only for the Permitted
Use of the Premises specified in the BASIC LEASE INFORMATION. Tenant shall not
do or permit to be done in, on or about the Premises, nor bring or keep or
permit to be brought or kept therein, anything that is prohibited by or will
conflict with any law, ordinance, rule, regulation or order now in force or that
may hereafter be enacted, or that is prohibited by any insurance policy carried
by Landlord for the Premises, or will in any way increase the existing rate of
(unless Tenant agrees to pay such increase), or disallow any fire rating or
sprinkler credit, or cause a cancellation of, or affect, any insurance for the
Premises. If Tenant causes any increase in the premium for any insurance
covering the Premises carried by Landlord, Tenant shall pay to Landlord, on
written demand as additional rent, the entire amount of such increase. Tenant
shall not do or permit anything to be done in or about the Premises that will in
any way unreasonably obstruct or unreasonably interfere with the rights of
Landlord or any other tenant. Tenant shall not use or allow the Premises to be
used for any unlawful activity, nor shall Tenant cause, maintain or permit any
nuisance in, on or about the Premises or commit or suffer to be committed any
waste in, on or about the Premises. Tenant shall not install any signs on the
Premises without the written consent of Landlord, except that Tenant shall have
the right to install a monument sign and a sign on the building, containing
Tenant's name on Tenant's customary logo format subject to statutes including
zoning ordinances, and all recorded private covenants, conditions and
restrictions. Tenant shall, at Tenant's expense, remove all such signs prior to
or upon termination of this Lease and repair any damage caused by the
installation or removal of such signs.
5.2 RULES AND REGULATIONS. Tenant shall faithfully observe and fully
comply with all reasonable, non-discriminatory rules and regulations ("Rules and
Regulations") from time to time made in writing by Landlord for the safety,
care, use and cleanliness of the
- 8 -
Property and the preservation of good order therein. If there is any conflict,
this Lease shall prevail over the Rules and Regulations.
ARTICLE 6
UTILITIES AND SERVICES
6.1 TENANT'S RESPONSIBILITIES. Tenant shall pay, directly to the
appropriate supplier before delinquency, for all electricity, water, gas, heat,
light, power, telephone, sewer, refuse disposal and other utilities and services
supplied to the Premises, together with all taxes, assessments, surcharges and
similar expenses relating to such utilities and services. Tenant shall furnish,
at its cost and expense, the Premises with all telephone service, window
washing, security service, janitor, scavenger and disposal services, and other
services required by Tenant for the use of the Premises permitted by this Lease.
Tenant shall furnish, at its cost and expense all electric light bulbs and tubes
and restroom supplies used in the Premises. Landlord shall not be in default
under this Lease or be liable for any damage or loss directly or indirectly
resulting from, nor shall the rent be abated (except as provided in Section 6.2
hereof) or a constructive or other eviction be deemed to have occurred by reason
of, any interruption of or failure to supply or delay in supplying any such
utilities and services or any limitation, curtailment, rationing or restrictions
on use of water, electricity, gas or any resource or form of energy or other
service serving the Premises or the Property, whether such results from
mandatory restrictions or voluntary compliance with guidelines.
6.2 ABATEMENT OF RENT WHEN TENANT IS PREVENTED FROM USING PREMISES. In
the event that Tenant is prevented from using, and does not use, the Premises or
any portion thereof for three (3) consecutive business days or ten (10) days in
any twelve (12) month period ("Eligibility Period") as a result of any damage or
destruction to the Premises which is not caused by Tenant or any repair,
maintenance or alteration performed by Landlord after the Commencement Date and
required by the Lease which is not caused by Tenant, that materially interferes
with Tenant's use of the Premises, or any failure to provide access to the
Premises or because of an eminent domain proceeding or because of the presence
of Hazardous Materials in, on or around the Premises or the Property which is
not caused by Tenant that could, in Tenant's reasonable business judgment, pose
a health risk to occupants of the Premises then Tenant's rent shall be abated or
reduced, as the case may be, after expiration of the Eligibility Period for such
time that Tenant continues to be so prevented from using, and does not use, the
Premises or a portion thereof, in the proportion that the rentable area of the
portion of the Premises that Tenant is prevented from using, and does not use,
bears to the total rentable area of the Premises. However, in the event that
Tenant is prevented from conducting, and does not conduct, its business in any
portion of the Premises for a period of time in excess of the Eligibility
Period, and the remaining portion of the Premises is not sufficient to allow
Tenant to effectively conduct its business therein, and if Tenant does not
conduct its business from such remaining portion, then for such time after
expiration of the Eligibility Period during which Tenant is so prevented from
effectively conducting its business therein, the rent for the entire Premises
shall be abated. If Tenant's right to abatement occurs because of an eminent
domain taking and/or because of damage or destruction to the Premises or
- 9 -
Tenant's property, Tenant's abatement period shall continue until Tenant has
been given sufficient time, and sufficient access to the Premises, to rebuild
the portion of the Premises it is required to rebuild, if any, to install its
property, furniture, fixtures, and equipment and to move in over one (1)
weekend. To the extent Tenant is entitled to abatement because of an event
covered by Sections 15.1 or 14.1, then the Eligibility Period shall not be
applicable. If a dispute arises between Landlord and Tenant pursuant to this
section, Landlord and Tenant shall meet and attempt in good faith to resolve
such dispute. If after such meeting, Landlord and Tenant do not reach a
resolution, either party may invite arbitration proceedings in accordance with
Section 19.10 by giving the other party written notice thereof.
ARTICLE 7
MAINTENANCE AND REPAIRS
7.1 QUALITY OF CONSTRUCTION - STANDARD FOR MAINTENANCE, REPAIRS AND
OPERATION. Landlord hereby warrants to Tenant that the Property and the Premises
to be constructed by Landlord or Landlord's contractor will be constructed and
operated in a first-class manner, free of all asbestos containing materials
("ACM") and in full compliance with all governmental regulations, ordinances,
and laws existing at the time of construction, including, but limited to, laws
pertaining to disabled access and Environmental Requirements (as hereinafter
defined) and all regulations and/or restrictions relating to the industrial
center in which the Premises is located (collectively, the "Applicable Laws").
All warranties made by Landlord's contractor or any subcontractor with respect
to the construction performed on the Property and/or Premises shall be made to
Tenant and Landlord. Landlord will be fully responsible for making all
alterations and repairs to the Property and the Premises, at Landlord's sole
cost and expense, (i) required in order to comply with the Americans with
Disabilities Act of 1990, 42 U.S.C. 12101 ET SEQ., as amended ("ADA"), (ii)
required to remove any and all ACM discovered at any time to have existed in the
Premises as of the Commencement Date, or (iii) resulting from or necessitated by
the failure by Landlord and/or Landlord's contractor to comply with the
Applicable Laws, or from Landlord's and/or Landlord's contractor's utilization
of Hazardous Materials in violation of Applicable Laws or that pose a health
risk to occupants of the Premises. Otherwise, Tenant shall maintain and operate
the Property and, subject to Landlord's repair obligations set forth in Section
7.2 below, the Premises, in excellent condition and repair, shall operate, and
provide services and security to, the Property, in a first-class manner
comparable to other first-class warehouse facilities in the vicinity of the
Property.
7.2 OBLIGATIONS OF LANDLORD. Landlord shall maintain and repair the
foundations, the roof and all other structural aspects of the Premises, unless
such repair or maintenance is required as a result of Tenant's negligence, in
which case Landlord is only required to maintain and repair to the extent the
costs of such maintenance and repair are covered by insurance proceeds received
by Landlord therefor. Tenant shall give Landlord written notice of the need for
any maintenance or repair for which Landlord is responsible, after which
Landlord shall have a reasonable opportunity to perform the maintenance or make
the repair, but in no event more than twenty-four (24) hours in the event of an
emergency
- 10 -
and no more than thirty (30) days in other cases, unless Landlord commences such
maintenance or repair within such thirty-day period, and thereafter diligently
prosecutes such maintenance or repair to completion. If Landlord fails to
perform any maintenance or make any repairs for which Landlord is responsible
within such time periods, Tenant shall have the right to perform such
maintenance or make such repairs at Landlord's expense. Landlord shall reimburse
Tenant within fifteen (15) days after receipt of an invoice from Tenant for all
expenses incurred by Tenant in performing such maintenance or making such
repair, plus interest thereon at the rate of ten percent (10%) per annum
("Interest Rate") from the date incurred to the date paid, and if Landlord fails
to do so, Tenant shall have the right to deduct such expenses from the next
installment(s) of the rent coming due hereunder. Except as expressly provided in
this Lease, Tenant waives its right under any statute to make repairs at
Landlord's expense or to terminate this Lease because of Landlord's failure to
keep the Premises in good order, condition and repair. Except as expressly
provided in this Lease, Tenant waives its rights under Arizona Revised Statutes
Section 33-343 with respect to Landlord's obligations for tenantability of the
Premises, and Tenant's right to cease paying rent and terminate the Lease. Any
damage to any part of the Property for which Landlord is responsible that is
caused by the negligence or willful misconduct of Tenant or any agent, officer,
employee, contractor, licensee or invitee of Tenant shall be repaired by
Landlord at Tenant's expense, and Tenant shall pay to Landlord, immediately upon
billing by Landlord, as additional rent, the cost of such repairs incurred by
Landlord plus interest thereon at the Interest Rate less any amounts of
insurance proceeds received by Landlord therefor.
7.3 OBLIGATIONS OF TENANT. Tenant shall have, at all times during the
term of this Lease and at Tenant's sole cost and expense, maintain and repair
the Property and the Premises and every part thereof (except only the parts for
which Landlord is expressly made responsible under this Lease) and all
equipment, fixtures and improvements therein (including windows, glass, plate
glass, doors, special fronts, entries, exterior walls, the interior surfaces of
exterior walls, interior walls, floors, dock boards, truck doors, dock bumpers,
plumbing fixtures and equipment, heating and air conditioning systems,
electrical components and mechanical systems), landscaped areas and parking
areas and keep of all of the foregoing clean and in good order and operating
condition, ordinary wear and tear excepted. Tenant shall not damage the Premises
or disturb the integrity and support provided by any wall. Tenant shall, at
Tenant's expense, promptly repair any damage to the Premises caused by Tenant or
any agent, officer, employee, contractor, licensee or invitee of Tenant. Tenant
shall take good care of the Premises and keep the Premises free from dirt,
rubbish, waste and debris at all times. Tenant shall not overload the floors in
the Premises or exceed the load-bearing capacity of the floors in the Premises,
which is 3,000 pounds. Tenant shall, at Tenant's expense, enter into a regularly
scheduled preventative maintenance and service contract with a maintenance
contractor approved in writing by Landlord for servicing all hot water, heating
and air conditioning systems and equipment in the Premises. The maintenance and
service contract shall include all services suggested by the equipment
manufacturer and shall become effective (and a copy shall be delivered to
Landlord) within thirty (30) days after the Commencement Date. Tenant shall, at
the end of the term of this Lease, surrender to
- 11 -
Landlord the Premises and all alterations, additions, fixtures and improvements
therein or thereto in the same condition as when received, ordinary wear and
tear and casualty damage excepted.
ARTICLE 8
ALTERATIONS OF THE PREMISES
8.1 NO ALTERATIONS BY TENANT. Tenant shall not make any alterations,
additions or improvements in or to the Premises or any part thereof, or attach
any fixtures or equipment thereto, without Landlord's prior written consent,
which consent shall not be unreasonably withheld, conditioned or delayed.
Notwithstanding the preceding sentence, Tenant may make alterations, additions
or improvements costing less than Five Thousand and 00/100 Dollars ($5,000.00)
in the aggregate, without Landlord's consent, provided such alterations,
additions or improvements will not materially adversely affect the structural,
exterior or roof elements of the Premises or the mechanical, electrical plumbing
or life safety systems of the Premises, but Tenant shall give prior written
notice of any such alterations, additions or improvements to Landlord. All
alterations, additions and improvements (except improvements made pursuant to
Exhibit "B", if any) in or to the Premises to which Landlord consents shall be
made by Tenant at Tenant's sole cost and expense as follows:
(a) Tenant shall submit to Landlord, for Landlord's written
approval, complete plans and specifications for all work to be
done by Tenant. Such plans and specifications shall be
prepared by responsible architect(s) and engineer(s), shall
comply with all applicable codes, laws, ordinances, rules and
regulations, shall not materially adversely affect any
systems, components or elements of the Premises, shall be in a
form sufficient to secure the approval of all government
authorities with jurisdiction over the Premises, and shall be
otherwise satisfactory to Landlord in Landlord's reasonable
discretion. Tenant shall pay all costs, including the fees and
expenses of the architect(s) and engineer(s), in preparing
such plans and specifications.
(b) Landlord shall notify Tenant within five (5) days of
Landlord's receipt of Tenant's request in writing whether
Landlord approves, or disapproves, such plans and
specifications, Landlord shall describe in writing the reasons
for disapproval. Tenant may submit to Landlord revised plans
and specifications for Landlord's prior written approval.
(c) All subsequent changes in the plans and specifications
approved by Landlord shall be subject to Landlord's prior
written approval. If Tenant wishes to make any such changes in
such approved plans and specifications, Tenant shall have such
architect(s) and engineer(s) prepare plans and specifications
for such change and submit them to Landlord for Landlord's
written approval. Landlord shall notify Tenant in writing
within five (5) days of Landlord's receipt of the revised
plans and specifications whether Landlord approves, or
disapproves, such changes
- 12 -
and, if Landlord disapproves such change, Landlord shall
describe in writing the reasons for disapproval. Tenant may
submit to Landlord revised plans and specifications for such
change for Landlord's written approval. After Landlord's
written approval of such change, such change shall become part
of the plans and specifications approved by Landlord.
(d) Tenant shall obtain and comply with all building permits
and other governmental permits and approvals required in
connection with the work. Tenant shall, through Tenant's
contractor, perform the work substantially in accordance with
(i) the plans and specifications approved in writing by
Landlord, (ii) the permits obtained by Tenant, and (iii) all
applicable codes, laws, ordinances, rules and regulations.
Under no circumstances shall Landlord be liable to Tenant for
any damage, loss, cost or expense incurred by Tenant on
account of any plans and specifications, contractors or
subcontractors, design of any work, construction of any work,
or delay in completion of any work, except to the extent that
the same results from a breach by Landlord of its obligations
under this Lease or from Landlord's gross negligence or
willful misconduct.
(e) Tenant shall give written notice to Landlord of the date
on which construction of any work will be commenced at least
ten (10) days prior to such date. Tenant shall keep the
Premises free from mechanics', materialmen's and all other
liens arising out of any work performed, labor supplied,
materials furnished or other obligations incurred by Tenant.
Tenant shall promptly and fully pay and discharge all claims
on which any such lien could be based; provided however, that
the Tenant shall have the right to contest the amount or
validity of any such lien, provided Tenant gives prior written
notice of such contest to Landlord, prosecutes such contest by
appropriate proceedings in good faith and with diligence, and,
upon request by Landlord, furnishes such bond as may be
required by law to protect the Premises from such lien.
Landlord shall have the right to post and keep posted on the
Premises any notices that may be provided by law or which
Landlord may deem to be proper for the protection of Landlord
and the Premises from such liens.
(f) Landlord shall, at the time Tenant requests Landlord's
consent to any alterations, addition or improvement, inform
Tenant in writing whether Landlord will require the removal of
the alteration, addition or improvement in question at the
expiration or earlier termination of this Lease. If Landlord's
consent is not required, Landlord shall have the right to
provide to Tenant a written statement as to whether Landlord
will require the removal of the alteration, addition or
improvement in question at the expiration or earlier
termination of this Lease.
8.2 LANDLORD'S PROPERTY. Except as otherwise agreed by the parties,
all alterations, additions, fixtures and improvements made pursuant to Exhibit
"B", whether temporary or permanent in character, made in or to the Premises by
Landlord or Tenant, shall
- 13 -
become part of the Premises and Landlord's property. All moveable furniture,
equipment, trade fixtures, computers, office machines, moveable partitions and
other personal property shall remain the property of Tenant. Upon termination of
this Lease, Tenant shall, at Tenant's expense, promptly remove all such moveable
furniture, equipment, trade fixtures, computers, office machines, movable
partitions and other personal property from the Premises and repair all damage
caused by any such removal.
ARTICLE 9
INDEMNIFICATION AND INSURANCE
9.1 LANDLORD'S INDEMNIFICATION. Landlord shall indemnify and defend
Tenant against and hold Tenant harmless from all claims, demands, losses, costs
and expenses, including reasonable attorneys' fees and disbursements, arising
from or related to any defect on the Property in existence on the Commencement
Date, or any default in the performance of Landlord's obligations, or any damage
to any property or any bodily or personal injury, illness or death of any person
occurring in, on or about the Premises or any part thereof, arising at any time,
to the extent caused by the negligence or willful misconduct of Landlord. This
Section 9.1 shall survive the termination of this Lease with respect to any
damage, bodily or personal injury, illness or death occurring prior to such
termination.
9.2 TENANT INDEMNIFICATION. Tenant shall indemnify and defend Landlord
against and hold Landlord harmless from all claims, demands, liabilities,
damages, losses, costs and expenses, including reasonable attorneys' fees and
disbursements, arising from or related to any use or occupancy of the Premises,
any default in the performance of Tenant's obligations, or any damage to any
property (including property of employees and invitees of Tenant) or any bodily
or personal injury, illness or death of any person (including employees and
invitees of Tenant) occurring in, on or about the Premises or any part thereof
arising at any time and from any cause whatsoever (except to the extent caused
by the negligence or willful misconduct of Landlord) or occurring outside the
Premises. This Section 9.2 shall survive the termination of this Lease with
respect to any damage, bodily or personal injury, illness or death occurring
prior to such termination.
9.3 TENANT'S LIABILITY INSURANCE. Tenant shall, at all times during
the term of this Lease and at Tenant's sole cost and expense, obtain and keep in
force comprehensive general liability, fire legal liability, and premises
operations insurance with a minimum combined single limit in the amount
specified in the BASIC LEASE INFORMATION per occurrence for bodily or personal
injury to, illness of, or death of persons and damage to property occurring in,
on or about the Premises, such insurance shall name Landlord and Landlord's
mortgagees, if any, as additional insureds, subject to Section 9.6. Tenant
shall, at Tenant's sole cost and expense, be responsible for insuring Tenant's
furniture, equipment, fixtures, computers, office machines and other personal
property.
9.4 WORKER'S COMPENSATION INSURANCE. Tenant shall, at all times during
the term of this Lease and at Tenant's sole cost and expense, obtain and keep in
force worker's compensation and employer's liability insurance in the state in
which the Premises are located.
- 14 -
9.5 PROPERTY INSURANCE. Landlord shall, at all times during the term
of this Lease, at Tenant's cost and expense, obtain and keep in force (a) a
policy or policies of insurance covering loss or damage to the Property,
including the Premises but excluding Tenant's fixture, equipment and tenant
improvements paid for by Tenant, in an amount equal to the full replacement
value thereof (without deduction for depreciation), as the same may exist from
time to time, providing protection against all perils included within the
classification of "all risk", as such terms is used in the insurance industry,
and specifically including fire, extended coverage, vandalism, malicious
mischief, flood and earthquake ( in the event flood and/or earthquake coverage
is required by the lender having a lien on the Property), special extended
perils, debris removal, and containing the "Replacement Cost Endorsement"; (b)
boiler and machinery insurance covering pressure vessels, air tanks, boilers,
machinery, pressure piping, heating, ventilation and air conditioning equipment,
and elevator and escalator equipment, provided the Premises contain equipment of
such nature; and (c) plate glass insurance in such amounts as Landlord may
reasonably determine if the Premises contain plate glass.
9.6 GENERAL REQUIREMENTS. All insurance required to be maintained by
Tenant under this Article 9 may be maintained under blanket policies. All
insurance required to be maintained by Tenant under this Article 9 and all
renewals thereof shall be issued by good and responsible companies qualified to
do and doing business in the state where the Premises are located and having a
rating in Best's Insurance Guide of at least A-XI. Each policy to be maintained
by Tenant shall expressly provide that the policy shall not be canceled or
altered without thirty (30) days' prior written notice to Landlord and shall
remain in effect notwithstanding any such cancellation or alteration until such
notice shall have been given to Landlord and such period of thirty (30) days
shall have expired. Notwithstanding anything herein to the contrary, Tenant
shall have no obligation to insure against claims based on or arising from the
negligence or willful misconduct of Landlord or Landlord's mortgagee. All
insurance under this Article 9 to be maintained by Tenant shall name Landlord
and Landlord's mortgagee, if any, as an additional insured, shall be primary and
noncontributing with any insurance which may be carried by Landlord, and shall
expressly provide that Landlord, although named as an additional insured, shall
nevertheless be entitled to recover under the policy for any loss, injury or
damage to Landlord, except for claims based on or arising from the negligence or
willful misconduct of Landlord or Landlord's mortgagee. Upon the issuance of
each such policy to be maintained by Tenant, Tenant shall deliver a certificate
thereof to Landlord for retention by Landlord. If Tenant fails to insure or
fails to furnish to Landlord upon written notice to do so any certificate
thereof as required, Landlord shall have the right from time to time to effect
such insurance for the benefit of Tenant or Landlord or both of them and all
premiums paid by Landlord shall be payable by Tenant as additional rent on
demand. Tenant shall pay to Landlord, immediately upon demand all costs incurred
by Landlord as a result of Tenant's failure to obtain and maintain in effect the
policies of insurance required under this Article 9.
9.7 WAIVER OF SUBROGATION. Tenant waives on behalf of all insurers
under all policies of property, liability and other insurance (excluding
worker's compensation) now of hereafter carried by Tenant insuring or covering
the Premises, or any portion or any
- 15 -
contents thereof, or any operations therein, all rights of subrogation which any
insurer might otherwise, if at all, have to any claims of Tenant against
Landlord. Landlord waives on behalf of all insurers under all policies of
property, liability and other insurance (excluding workers' compensation) now or
hereafter carried by Landlord insuring or covering the Premises or any portion
or any contents thereof, or any operations therein, all rights of subrogation
which any insurer might otherwise, if at all, have to any claims of Landlord
against Tenant.
9.8 LANDLORD'S LIABILITY INSURANCE. At Landlord's election and
expense, Landlord may obtain and keep in force at all times during the term of
this Lease comprehensive general liability, fire legal liability and premises
operations insurance with a minimum combined single limit in the amount
specified in the BASIC LEASE INFORMATION per occurrence for bodily or personal
injury to, illness of, or death of persons and damage to property occurring in,
on or about the Property.
9.9 EXCULPATION OF MEMBERS. Tenant hereby agrees that members
("Members") of Landlord shall not be personally liable solely as a result of
acting as Members of Landlord for injury to Tenant's business, or any loss of
income therefrom, or for damage to the goods, wares, merchandise or other
property of Tenant, Tenant's employees, invitees, customers, or any other person
in, on or about the Premises or Property or for any other loss or consequential
damage of any nature whatsoever, nor shall the Members be liable for injury to
the person of Tenant, Tenant's employees, agents or contractors, whether damage
or injury is caused by results from fire, steam, electricity, gas, water or
rain, or from the breakage, leakage, obstruction or other defects of pipes,
sprinklers, wires, appliances, plumbing, heating, ventilation, air conditioning,
life safety, mechanical and/or electrical systems, or lighting fixtures, or from
any other cause, whether the said damage or injury results from conditions
arising on the Premises or from other sources or places where the resulting
damage or injury occurs on or about the Premises, and regardless of whether the
cause of such damage or injury, or the means of repairing the same is
inaccessible to Tenant. Notwithstanding the foregoing, this Section 9.9 shall
have no effect if such damage or injury is caused by the gross negligence or
willful misconduct of the Members.
ARTICLE 10
COMPLIANCE WITH LEGAL REQUIREMENTS
10.1 COMPLY WITH LAW. Unless this Lease otherwise allocates the
responsibility for compliance to Landlord, Tenant shall at Tenant's sole cost
and expense, promptly comply with all laws, ordinances, rules, regulations,
orders and other requirements of any government or public authority now in force
or that may hereafter be in force, with all other requirements of any board of
fire underwriters or other similar body now or hereafter constituted, and with
all directions and certificates of occupancy issued pursuant to any law by any
governmental agency or officer, insofar as any thereof relate to or are required
by the condition, use of occupancy of the Premises or the operation, use or
maintenance of any personal property, fixtures, machinery, equipment or
improvements in the Premises, but Tenant shall not be required to make
structural changes or changes
- 16 -
costing in excess of Ten Thousand and 00/100 Dollars ($10,000) cumulatively,
unless such changes are related to or required by Tenant's acts or unique use of
the Premises or by improvements made by or for Tenant.
ARTICLE 112
ASSIGNMENT OR SUBLEASE
11.1 PROHIBITION. Tenant shall not, directly or indirectly, without
the prior written consent of Landlord (which consent shall not be unreasonably
withheld, delayed or conditioned), assign this Lease or any interest herein or
sublease the Premises or any part thereof, or permit the use or occupancy of the
Premises by any person or entity other than Tenant. Tenant shall not, directly
or indirectly, without the prior written consent of Landlord (which consent
shall not be unreasonably withheld, delayed or conditioned), pledge, mortgage or
hypothecate this Lease or any interest herein. This Lease shall not, nor shall
any interest herein, be assignable as to the interest of Tenant involuntarily or
by operation of law without the prior written consent of Landlord. Any of the
foregoing acts without such prior written consent of Landlord shall be void and
shall, at the option of Landlord, constitute a default that entitles Landlord to
terminate this Lease. Notwithstanding anything to the contrary contained herein,
Tenant may assign this Lease at any time, or sublease all or part of the
Premises, without Landlord's prior written consent, to any entity that acquires
all or part of Tenant, or that is acquired in whole or in part by Tenant, or
that is controlled directly or indirectly by Tenant, or that controls, directly
or indirectly, Tenant ("Affiliate"), or that owns or is owned by an Affiliate,
so long as such transaction was not entered into as a subterfuge to avoid the
obligations or restrictions of this Lease. Tenant agrees that the instrument by
which any assignment or sublease to which Landlord consents is accomplished
shall expressly provide that the assignee or subtenant will perform all of the
covenants to be performed by Tenant under this Lease (in the case of a sublease,
only insofar as such covenants relate to the portion of the Premises subject to
such sublease) as and when performance is due after the effective date of the
sublease and that Landlord will have the right to enforce such covenants
directly against assignee or subtenant. Any purported assignment or sublease
without an instrument containing the foregoing provisions shall be void. Tenant
shall in all cases, regardless whether such assignment requires the consent of
Landlord, remain liable for the performance by any assignee or subtenant of all
such covenants.
11.2 LANDLORD'S CONSENT OR TERMINATION. If Tenant wishes to assign
this Lease or sublease all or any part of the Premises and Tenant is required to
obtain Landlord's consent pursuant to Section 11.1, Tenant shall give written
notice to Landlord identifying the intended assignee or subtenant by name and
address and specifying all of the terms of the intended assignment or sublease.
Tenant shall give Landlord such additional information concerning the intended
assignee or subtenant (including complete financial statements and a business
history) or the intended assignment or sublease (including true copies thereof)
as Landlord requests. For a period of twenty (20) days after such written notice
is given by Tenant, Landlord shall have the right, by giving written notice to
Tenant, to consent in writing to the intended assignment or sublease, unless
Landlord determines not to consent. If Landlord objects to such assignment or
sublease, Landlord
- 17 -
shall notify Tenant in writing of the basis for Landlord's objection. Without
limiting any other provision of this Article 11, Landlord's criteria for
determining whether to consent to an assignment or sublease proposed by Tenant
shall not be more stringent than the criteria Landlord is obligated to or would
apply if another large creditworthy tenant of the Property was requesting such
consent. If Landlord does not deliver notice of Landlord's consent or refusal to
consent to Tenant within such twenty (20) day period, Landlord shall be deemed
to have consented to such assignment or sublease.
11.3 COMPLETION. If Landlord consents in writing, Tenant may complete
the intended assignment or sublease subject to the following covenants: (a) the
assignment or sublease shall be on the same terms as set forth on the written
notice given by Tenant to Landlord, (b) no assignment or sublease shall be valid
until an executed duplicate original of such assignment or sublease, in
compliance with Section 11.1 hereof has been delivered to Landlord; and (c)
Tenant reaffirms in writing its continued liability for the performance by an
assignee or subtenant of all of the covenants to be performed by Tenant under
the Lease.
11.4 TENANT NOT RELEASED. No assignment or sublease whatsoever shall
release Tenant from Tenant's obligations and liabilities under this Lease or
alter the primary liability of Tenant to pay all rent and to perform all
obligations to be paid and performed by Tenant. No assignments or sublease shall
amend or modify this Lease in any respect, and every assignment and sublease
shall be subject and subordinate to this Lease. The acceptance of rent by
Landlord from any other person or entity shall not be deemed to be a waiver by
Landlord of any provision of this Lease. Consent to one assignment or sublease
shall not be deemed consent to any subsequent assignment or sublease. Tenant
shall pay to Landlord all direct costs and shall reimburse Landlord for all
reasonable expenses incurred by Landlord in connection with any assignment or
sublease requested by Tenant, provided such costs and expenses do not exceed
Five Hundred and 00/100 Dollars ($500.00). If any assignee, subtenant or
successor of Tenant defaults in the performance of any obligation to be
performed by Tenant under this Lease, Landlord may proceed directly against
Tenant without the necessity of exhausting remedies against such assignee,
subtenant or successor.
ARTICLE 12
ENTRY BY LANDLORD
12.1 ENTRY. Landlord shall have the right to enter the Premises at any
time during the Business Hours and upon at least twenty-four (24) hours' prior
notice (except in the event of an emergency, in which case no prior notice shall
be required), and at Tenant's option, accompanied at all times during such entry
by an employee or representative of Tenant, to (a) inspect the Premises, (b)
exhibit the Premises to prospective purchasers, lenders or tenants, (c)
determine whether Tenant is performing all of Tenant's obligations, (d) supply
any service to be provided by Landlord, (e) post notices of nonresponsibility,
and, and (f) make any repairs to the Premises, or to make any repairs to utility
services, provided all such work shall be done promptly as reasonably
practicable and so as to cause as little interference to Tenant as reasonably
practicable. Tenant may
- 18 -
designate certain areas of the Premises as "Secured Areas" should Tenant require
such areas for the purposes of securing certain valuable property or
confidential information. Landlord may not enter such Secured Areas except in
the case of emergency or in the event of a Landlord inspection, in which case
Landlord shall provide Tenant with three (3) days' written notice of the
specific date and time of such Landlord inspection. Tenant waives all claims for
damages for any injury or inconvenience to or interference with Tenant's
business, any loss of occupancy or quiet enjoyment of the Premises or any other
loss occasioned by such entry, except to the extent caused by Landlord's gross
negligence or willful misconduct. Landlord shall have the right to use any and
all means that Landlord may deem reasonably necessary to open all doors in, or
about the Premises (excluding Tenant's vaults, safes and other Secured Areas
designated in writing by Tenant) in an emergency to obtain entry to the
Premises. Any entry to the Premises obtained by Landlord by any such means shall
not be construed or deemed to be a forcible or unlawful entry into or a detainer
of the Premises or an eviction, actual on constructive, of Tenant from the
Premises or any portion thereof.
ARTICLE 13
EVENT OF DEFAULT AND REMEDIES
13.1 DEFAULT BY TENANT. The occurrence of any one or more of the
following events ("Event of Default") shall constitute a breach of this Lease by
Tenant:
(a) Tenant fails to pay Base Rent, or any additional monthly
rent under Section 4.1 hereof, or any additional rent or other
amount of money or charge payable by Tenant hereunder as and
when such rent becomes due and payable and such failure
continues for more than ten (10) days after such rent or other
amount of money or charge is due; or
(b) Tenant fails to perform or breaches any other agreement
or covenant of this Lease to be performed or observed by
Tenant as and when performance or observance is due and such
failure or breach continues for more than thirty (30) days
after Landlord gives written notice thereof to Tenant;
provided, however, that if, by the nature of such agreement or
covenant, such failure or breach cannot reasonably be cured
within such period of thirty (30) days, an Event of Default
shall not exist as long as Tenant commences with due diligence
and dispatch the curing of such failure or breach within such
period of thirty (30) days and, having so commenced,
thereafter prosecutes with diligence and dispatch and
completes the curing of such failure or breach; or
(c) Tenant (i) files, or consents by answer or otherwise to
the filing against it of, a petition for relief or
reorganization or arrangement or any other petition in
bankruptcy or for liquidation or to take advantage of any
bankruptcy, insolvency or other debtors' relief law of any
jurisdiction, (ii) makes an assignment for the benefit of its
creditors, or (iii) consents to the appointment of a
custodian, receiver, trustee or other officer with similar
powers of Tenant or of any substantial part of Tenant's
property; or
- 19 -
(d) Without consent by Tenant, a court or government
authority enters an order, and such order is not vacated
within sixty (60) days, (i) appointing a custodian, receiver,
trustee or other officer with similar powers with respect to
Tenant or with respect to any substantial part of Tenant's
property, or (ii) constituting an order for relief or
approving a petition for relief or reorganization or
arrangement or any other petition in bankruptcy or for
liquidation or to take advantage of any bankruptcy, insolvency
or other debtors' relief law of any jurisdiction, or (iii)
ordering the dissolution, winding-up or liquidation of Tenant;
or
(e) This Lease or any estate of Tenant hereunder is levied
under any attachment or execution and such attachment or
execution is not vacated within sixty (60) days; or
(f) Tenant vacates or abandons the Property at any time prior
to the expiration or earlier termination of this Lease except
as permitted under the Lease.
13.2 TERMINATION. If an Event of Default occurs, Landlord shall have
the right at any time to give a written termination notice to Tenant and, on the
date specified in such notice, Tenant's right to possession shall terminate and
this Lease shall terminate. Upon such termination, Landlord shall have the full
and immediate right to possession of the Premises, and Landlord shall have the
right to recover from Tenant all unpaid rent that had been earned at the time of
termination, the present value of all unpaid rent for the balance of the term of
this Lease after termination less the amount of such rental loss that Tenant
proves could have been reasonably avoided, and all the detriment caused by
Tenant's failure to perform all of Tenant's obligations under this Lease,
including but not limited to the cost of recovering possession of the Premises,
expenses of reletting, the cost of necessary repair, renovation and alteration
of the Premises and any real estate commissions actually paid.
13.3 CONTINUATION. If an Event of Default occurs, this Lease shall
continue in effect for so long as Landlord does not terminate Tenant's right to
possession, and Landlord shall have the right to enforce all of its rights and
remedies under this Lease, including the right to recover all rent as it becomes
due under this Lease. Acts of maintenance or preservation or efforts to relet
the Premises or the appointment of a receiver upon initiative of Landlord to
protect Landlord's interest under this Lease, shall not constitute a termination
of Tenant's right to possession unless written notice of termination is given by
Landlord to Tenant.
13.4 REMEDIES CUMULATIVE. Upon the occurrence of an Event of Default,
Landlord shall the right to exercise and enforce all rights and remedies granted
or permitted by law. The remedies provided for in this Lease are cumulative and
in addition to all other remedies available to Landlord at law or equity by
statute or otherwise. Exercise by Landlord of any remedy shall not be deemed to
be an acceptance or surrender of the Property by Tenant, either by agreement or
by operation of law. Surrender of the Property can be affected only by the
written agreement of Landlord and Tenant.
- 20 -
13.5 TENANT'S PRIMARY DUTY. All agreements and covenants to be
performed or observed by Tenant under this Lease shall be at Tenant's sole cost
and expense and without any abatement of rent, except as expressly provided
herein. If Tenant fails to pay any sum of money to be paid by Tenant or to
perform any other act to be performed by Tenant under this Lease after notice
and the passage of any applicable cure period, Landlord shall have the right,
but shall not be obligated, and without waiving or releasing Tenant from any
obligations of Tenant, to make any such payment or to perform any such other act
on behalf of Tenant in accordance with this Lease. All sums so paid by Landlord
and all necessary incidental costs shall be deemed additional rent hereunder and
Tenant shall pay the same to Landlord on written demand, together with interest
on all such sums from the date of expenditure by Landlord to the date of
repayment by Tenant at the Interest Rate.
13.6 ABANDONED PROPERTY. If Tenant is dispossessed by process of law
or otherwise, any movable furniture, equipment, trade fixtures or personal
property belonging to Tenant and left in the Premises for more than thirty (30)
days after Tenant is dispossessed of the Premises shall, at the option of
Landlord, be deemed to be abandoned and become the property of Landlord, and
Landlord shall have the right to sell or otherwise dispose of such personal
property in any commercially reasonable manner.
13.7 LANDLORD DEFAULT. If Landlord defaults under this Lease, Tenant
shall give written notice to Landlord specifying such default with
particularity, and Landlord shall have thirty (30) days after receipt of such
notice within which to cure such default, or, if such default cannot be cured
within thirty (30) days, such additional period of time as is reasonably
necessary to effectuate such cure, provided Landlord diligently and with
dispatch pursues the cure to completion. If Landlord fails to cure any such
default within the time periods specified herein, Tenant shall have the right to
take all actions reasonably necessary to cure such default, at Landlord's
expense. Landlord shall reimburse Tenant within fifteen (15) days after receipt
of an invoice from Tenant for all expenses incurred by Tenant in curing such
default, plus interest thereon at the Interest Rate from the date incurred to
the date paid, and if Landlord fails to do so, Tenant shall have the right to
deduct such expenses from the next installment(s) of rent coming due hereunder.
ARTICLE 14
DAMAGE OR DESTRUCTION
14.1 RESTORATION. If the Property or Premises, or any part thereof, is
damaged by fire or other casualty before the Commencement Date or during the
term of this Lease, and this Lease is not terminated pursuant to Section 14.2
hereof, Landlord shall repair such damage and restore the Property and the
Premises to substantially the same condition in which the Property and the
Premises existed before the occurrence of such fire or other casualty and this
Lease shall, subject to this Section 14.1, remain in full force and effect. If
such fire or other casualty damages the Premises or an area of the Property
necessary for Tenant's use and occupancy of the Premises, then, during the
period the Premises are rendered unusable by such damage, Tenant shall be
entitled to a reduction in
- 21 -
Base Rent in the proportion that the area of the Premises rendered unusable by
such damage bears to the total area of the Premises. Landlord shall not be
obligated to repair any damage to, or to make any replacement of, any movable
furniture, equipment, trade fixtures or personal property in the Premises.
Tenant shall, at Tenant's sole cost and expense, repair and replace all such
movable furniture, equipment, trade fixtures and personal property.
14.2 TERMINATION OF LEASE. If the Premises, or any part thereof, is
damaged by fire or other casualty before the Commencement Date or during the
term of this Lease and (a) such fire or casualty occurs during the last twelve
(12) months of the term of this Lease and the repair and restoration work to be
performed by Landlord in accordance with Section 14.1 hereof cannot, as
reasonably estimated by Landlord, by completed within four (4) months after the
occurrence of such fire or other casualty, or (b) the repair and restoration
work to be performed by Landlord in accordance with Section 14.1 hereof cannot,
as reasonably estimated by Landlord, be completed within six (6) months after
the occurrence of such fire or other casualty, then, in any such event, either
Tenant or Landlord shall have the right, by giving written notice to the other
party within sixty (60) days after the occurrence of such fire or other
casualty, to terminate this Lease as of the date of such casualty. Landlord
shall also have the right to terminate if the Premises is destroyed by an event
for which Landlord is not required by this Lease to maintain insurance
(exclusive of any deductible). If neither Landlord or Tenant exercises the right
to terminate this Lease in accordance with this Section 14.2, Landlord shall
repair such damage and restore the Premises in accordance with Section 14.1
hereof and this Lease shall, subject to Section 14.1 hereof, remain in full
force and effect. A total destruction of the Premises shall automatically
terminate this Lease effective as of the date of such total destruction.
ARTICLE 15
EMINENT DOMAIN
15.1 CONDEMNATION. Landlord shall have the right to terminate this
Lease if any part (but less than all) of the Premises or any substantial part of
the Property (whether or not it includes the Premises) is taken by exercise of
the power of eminent domain before the Commencement Date or during the term of
this Lease. Tenant shall have the right to terminate this Lease if any portion
of the Premises or the Property is taken by exercise of the power of eminent
domain before the Commencement Date or during the term of this Lease and the
remaining portion of the Property is not reasonably suitable for Tenant's
purposes. In each such case, Landlord and Tenant shall exercise such termination
right by giving written notice to the other within thirty (30) days after the
date of such taking. If either Landlord or Tenant exercises such right to
terminate this Lease in accordance with this Section 15.1, this Lease shall
terminate as of the date of such taking. If neither Landlord nor Tenant
exercises such right to terminate this Lease in accordance with this Section
15.1, this Lease shall terminate as to the portion of the Premises so taken as
of the date of such taking and shall remain in force and effect as to the
portion of the Premises not so taken, Landlord shall restore the Premises to as
near the same condition as the Premises was in prior to the taking, and the Base
Rent shall be reduced as of the date of
- 22 -
such taking in the proportion that the area of the Premises so taken bears to
the total area of the Premises. If all of the Premises is taken by exercise of
the power of eminent domain before the Commencement Date or during the term of
this Lease, this Lease shall terminate as of the date of such taking.
15.2 AWARD. If all or any part of the Premises is taken by exercise of
the power of eminent domain, all awards, compensation, damages, income, rent and
interest payable in connection with such taking shall, except as expressly set
forth in this Section 15.2, be paid to and become the property of Landlord, and
Tenant hereby assigns to Landlord all of the foregoing. Tenant shall have the
right to claim and receive directly from the entity exercising the power of
eminent domain only the share of any award determined to be owing to Tenant for
the taking of improvements installed by Tenant in the portion of the Premises so
taken, for the taking of Tenant's movable furniture, equipment, trade fixtures
and personal property, for loss of goodwill, for interference with or
interruption of Tenant's business, for removal and relocation expenses and for
the value of the leasehold estate created by this Lease and any unexpired term
of this Lease; provided, however, such award shall not reduce the compensation
otherwise payable to Landlord.
15.3 DEFINITION OF TAKING. As used herein, a "taking" means the
acquisition of all or part of the Premises for a public use by exercise of the
power of eminent domain or voluntary conveyance in lieu thereof and the taking
shall be considered to occur as of the earlier of the date on which possession
of the Premises (or part so taken) by the entity exercising the power of eminent
domain is authorized as stated in an order for possession or the date on which
title to the Premises (or part so taken) vests in the entity exercising the
power of eminent domain.
ARTICLE 16
SUBORDINATION AND SALE
16.1 SUBORDINATION. This Lease shall be subject and subordinate at all
times to the lien of all mortgages and deeds of trust securing any amount or
amounts whatsoever which may now exist or hereafter be placed on or against the
Premises or on or against Landlord's interest or estate therein, all without the
necessity of having further instruments executed by Tenant to effect such
subordination. If Landlord or any mortgagee shall elect to have this Lease prior
to the lien of its mortgage or deed of trust, and shall give written notice
thereof to Tenant, this Lease shall be deemed prior to such mortgage or deed of
trust. Tenant agrees to execute any documents required to effectuate such
subordination or to make this Lease prior to the lien of any mortgage or deed of
trust. Notwithstanding the foregoing, in the event of a foreclosure of any such
mortgage or deed of trust or of any other action or proceeding for the
enforcement thereof, or of any sale thereunder, this Lease shall not be
terminated or extinguished, nor shall the rights and possession of Tenant
hereunder be disturbed (except that, at any time when Event of Default by Tenant
exists under this Lease, any person who acquires Landlord's interest hereunder
shall have all of the rights and remedies provided under Article 13), and Tenant
shall attorn to the person who acquires the Landlord's interest hereunder
through any such mortgage or deed of trust. Tenant agrees to execute,
acknowledge and deliver upon
- 23 -
demand such further instruments evidencing such subordination of this Lease to
the lien of all such mortgages and deeds of trust as may reasonably be required
by Landlord. Landlord shall provide Tenant with, and the effectiveness of this
Section 16.1 is conditioned on Landlord's delivering to Tenant, a nondisturbance
agreement conforming to the provisions of this Section 16.1, in the form
attached hereto as Exhibit "D" and by this reference incorporated herein, from
all current and future mortgagees, beneficiaries and ground lessors of Landlord.
16.2 SALE OF THE PROPERTY. If the original Landlord hereunder, or any
successor owner of the Premises, sells or conveys the Premises, all liabilities
and obligations on the part of the original Landlord, or such successor owner,
under this Lease accruing after such sale or conveyance shall terminate and the
original Landlord, or such successor owner, shall automatically be released
therefrom, and thereupon all such liabilities and obligations shall be binding
upon the new owner, provided such new owner has assumed in writing all
obligations of the original Landlord under this Lease. Tenant agrees to attorn
to such new owner.
ARTICLE 17
ESTOPPEL CERTIFICATE
17.1 REQUIRED CERTIFICATION. At any time and from time to time, Tenant
shall, within fifteen (15) days after written request by Landlord, execute,
acknowledge and deliver to Landlord an estoppel certificate in the form attached
hereto as Exhibit "E" and by this reference incorporated herein, certifying: (a)
that this Lease is unmodified and in full force and effect (or, if there have
been modifications, that this Lease is in full force and effect as modified and
stating the date and nature of each modification); (b) the Commencement Date and
the Expiration Date determined in accordance with Article 2 hereof and the date,
if any, to which all rent and other sums payable hereunder have been paid; (c)
that no notice has been received by Tenant of any default by Tenant hereunder
which has not been cured, except as to default specified in such certificate;
and (d) that Landlord is not in default under this Lease, except as to defaults
specified in such certificate. Any such certificate may be relied upon by
Landlord and any actual or prospective purchaser or mortgage lender of the
Premises or any part thereof. If Tenant does not deliver such certificate to
Landlord within such fifteen (15) day period, Tenant shall be estopped from
making any claims to the contrary that: (a) this Lease is unmodified and in full
force and effect; (b) the Commencement Date, the Expiration Date and the date to
which rent has been paid all are as set forth on the estoppel certificate; (c)
Tenant has not received any notice of default by Tenant under this Lease that
has not been cured; and (d) Landlord is not in default under this Lease.
Landlord hereby agrees to provide to Tenant an estoppel certificate signed by
Landlord, containing the same types of information, and within the same periods
of time, as are set forth in the estoppel certificate described above, except
such changes as are reasonably necessary to reflect that the estoppel
certificate is being granted and signed by Landlord to Tenant or Tenant's
lender, assignee or sublessee, rather than from Tenant to Landlord or to
Lender's lender or purchaser. In the event Landlord or Tenant requests that the
other party hereto execute an estoppel certificate, the requesting party shall
reimburse the other party for all direct
- 24 -
costs and reasonable expenses incurred by the other party in reviewing,
negotiating and executing such estoppel certificate, provided such costs and
expenses do not exceed Five Hundred and 00/100 Dollars ($500.00) per request.
ARTICLE 18
NOTICES
18.1 METHOD. All requests, approvals, consents, notices and other
communications given by Landlord or Tenant under this Lease shall be properly
given only if made in writing and either deposited in the United States mail,
postage prepaid, certified mail with return receipt requested, or delivered by
hand (which may be through a messenger or recognized delivery, courier or air
express service) and addressed as follows: To Landlord at the address of
Landlord specified in the BASIC LEASE INFORMATION, or at such other place as
Landlord may from time to time designate in a written notice to Tenant; and to
Tenant at the address of Tenant specified in the BASIC LEASE INFORMATION, or at
such other place as Tenant may from time to time designate in a written notice
to Landlord. Such requests, approvals, consents, notices and other
communications shall be effective on the date of receipt (evidenced by the
certified mail receipt) if mailed or on the date of hand delivery if hand
delivered. If any such request, approval, consent, notice or other communication
is not received or cannot be delivered due to a change in the address of the
receiving party of which notice was not previously given to the sending party or
due to a refusal to accept by the receiving party, such request, approval,
consent, notice or other communication shall be effective on the date delivery
is attempted. Any request, approval, consent, notice or other communication
under this Lease may be given on behalf of a party by the attorney for such
party.
ARTICLE 19
MISCELLANEOUS
19.1 GENERAL. The words "Landlord" and "Tenant" as used herein shall
include the plural as well as the singular and shall include, as appropriate,
each of their employees, officers, agents, contractors, invitees and licensees.
The words "include", "includes" and "including" shall be deemed to be followed
by the phrase "without limitation". If there is more than one Tenant, the
obligations hereunder imposed upon Tenant shall be joint and several. Time is of
the essence of this Lease and each and all of its provisions. This Lease shall
benefit and bind Landlord and Tenant and the permitted personal representatives,
heirs, successors and assigns of Landlord and Tenant. If any provision of this
Lease is determined to be illegal or unenforceable, such determination shall not
affect any other provision of this Lease and all such other provisions shall
remain in full force an effect. Neither Landlord nor Tenant shall record this
Lease or any memorandum or short form of it, without the other party's consent.
This Lease shall be governed by and construed in accordance with the laws of the
state in which the Premises is located.
19.2 NO WAIVER. The waiver by Landlord or Tenant of any breach of any
covenant in this Lease shall not be deemed to be a waiver of any subsequent
breach of the same or any other covenant in this Lease, nor shall any custom or
practice which may
- 25 -
grow up between Landlord and Tenant in the administration of this Lease be
construed to waive or to lessen the right of Landlord or Tenant to insist upon
the performance by Landlord or Tenant in strict accordance with this Lease.
19.3 ATTORNEY'S FEES. If there is any legal action or proceeding
between Landlord and Tenant to enforce this Lease or to protect or establish any
right or remedy under this Lease, the unsuccessful party to such action or
proceeding shall pay to the prevailing party all costs and expenses, including
reasonable attorneys' fees and disbursements, incurred by such prevailing party
in such action or proceeding and in any appeal in connection therewith. If such
prevailing party recovers a judgment in any such action, proceeding or appeal,
such costs, expenses and attorneys' fees and disbursements shall be included in
and as a part of such judgment.
19.4 EXHIBITS. Exhibit "A" (Plan(s) Outlining the Premises and
Property), Exhibit "B" (Work Letter), Exhibit "C" (Memorandum Confirming Term),
Exhibit "D" (Subordination, Non-Disturbance and Attornment Agreement) and
Exhibit "E" (Estoppel Certificate) are attached hereto and made a part of this
Lease.
19.5 BROKERS. Landlord shall pay all fees and expenses of the real
estate brokers specified in the BASIC LEASE INFORMATION ("Brokers"), pursuant to
a separate agreement between Landlord and Brokers. Each of Landlord and Tenant
warrants and represents to the other party that Landlord or Tenant, as the case
may be, has negotiated this Lease directly with the Brokers and has not
authorized or employed, or acted by implication to authorize or to employ, any
real estate broker other than Brokers to act for Landlord or Tenant, as the case
may be, in connection with this Lease.
19.6 ENTIRE AGREEMENT. There are no oral agreements between Landlord
and Tenant affecting this Lease, and this Lease supersedes and cancels any and
all previous negotiations, arrangements, brochures, offers, agreements and
understandings, oral or written, if any, between Landlord and Tenant or
displayed by Landlord or Tenant with respect to the subject matter of this Lease
and the Premises. There are no commitments, representations or assurances
between Landlord and Tenant or between any real estate broker and Tenant other
than those expressly set forth in this Lease and all reliance with respect to
any commitments, representations or assurances is solely upon commitments,
representations and assurances expressly set forth in this Lease. This Lease may
not be amended or modified in any respect whatsoever except by an agreement in
writing signed by Landlord and Tenant.
19.7 DUTY TO ACT REASONABLY. Any time the consent of Landlord or
Tenant is required, such consent shall not be unreasonably withheld, conditioned
or delayed, unless expressly provided otherwise herein. Whenever this Lease
grants Landlord or Tenant the right to take action, exercise discretion,
establish rules and regulations or make allocations or other determinations,
Landlord and Tenant shall act reasonably and in good faith and take no action
that might result in the frustration of the reasonable expectations of a
sophisticated landlord and sophisticated tenant concerning the benefits to be
enjoyed under this Lease.
- 26 -
19.8 DAYS. All references herein to less than "ten (10) days" shall
mean business days, and all references to "notice" shall mean written notice
given in compliance with Section 18.1. All references in the Lease to "month" or
"months" shall be deemed to include the actual number of days in such actual
month or months.
19.9 COUNTERPARTS. This Lease may be signed in multiple counterparts
which, when signed by all parties, shall constitute a binding agreement.
19.10 ARBITRATION. The initiation of arbitration proceedings pursuant
to Section 6.2 shall be with the American Arbitration Association under the
Commercial Arbitration Rules of the American Arbitration Association. The
decision of the Arbitrator shall be final and binding on the parties and
enforceable in a court of competent jurisdiction. The parties shall bear their
respective attorneys' fees and costs in connection with such arbitration, except
as the Arbitrator shall otherwise determine, and each such party shall bear
one-half (1/2) of the fees and expenses of the Arbitrator and of the American
Arbitration Association in connection with such arbitration.
ARTICLE 20
HAZARDOUS MATERIALS
20.1 DEFINITION OF HAZARDOUS MATERIALS. As used herein, the term
"Hazardous Material" means any hazardous or toxic substance, material or waste,
or any pollutant or contaminate, or words of similar import, which is or becomes
regulated by any local governmental authority, the state in which the Premises
are located, or the United States Government. The term "Hazardous Material"
includes, but is not limited to, any material or substance which is (i)
designated as a "hazardous substance" pursuant to Section 311 of the Federal
Water Pollution Control Act (33 U.S.C. Section 1317), (ii) defined as a
"hazardous waste" pursuant to Section 1004 of the Federal Resource Conservation
and Recovery Act, 42 U.S.C. Section 6901, et seq. (42 U.S.C. Section 6903),
(iii) defined as a "hazardous substance" pursuant to Section 101 of the
Comprehensive Environmental Response Compensation and Liability Act (42 U.S.C.
Section 9601, et seq.), (iv) asbestos, (v) petroleum (including crude oil or any
fraction thereof, natural gas, natural gas liquids, liquefied natural gas,
synthetic natural gas usable for fuel, or any mixture thereof), (vi) petroleum
products, (vii) polychlorinated biphenyls, (viii) urea formaldehyde, (ix) radon
gas, (x) radioactive matter, (xi) medical waste, and (xii) chemicals which may
cause cancer or reproductive toxicity.
20.2 DEFINITION OF ENVIRONMENTAL REQUIREMENTS. As used herein, the
term "Environmental Requirements" means all laws, ordinances, rules,
regulations, orders and other requirements of any government or public authority
now in force or which may hereinafter be in force relating to protection of
human health or the environment from Hazardous Material, including all
requirements pertaining to reporting, licensing, permitting, investigation and
remediation of emissions, discharges, storage, disposal or releases of Hazardous
Materials and all requirements pertaining to the protection of the health and
safety of employees or the public with respect to Hazardous Material.
20.3 PROHIBITED ACTIVITIES. Tenant shall not directly or indirectly
permit or conduct the handling, use, deposit, generation, treatment, storage or
disposal in, on or
- 27 -
about the Premises or Property of any Hazardous Material in excess of permitted
levels or reportable quantities under applicable Environmental Requirements
without prior written notice to Landlord. Any such handling, use, deposit,
generation, treatment, storage or disposal of any Hazardous Material permitted
by Landlord hereunder shall be in compliance with all Environmental
Requirements.
20.4 NOTICE OF VIOLATIONS. Tenant shall, within five (5) days after
Tenant's receipt thereof, give written notice to Landlord of any notice or other
communication regarding any (a) actual or alleged violation of Environmental
Requirements by Tenant or with respect to the Premises, (b) actual or threatened
migration of Hazardous Material from the Premises, or (c) the existence of
Hazardous Material in or on the Premises or regarding any actual or threatened
investigation, inquiry, lawsuit, claim, citation, directive, summons,
proceedings, complaint, notice, order, writ or injunction relating to any of the
foregoing.
20.5 TENANT INDEMNIFICATION. Tenant shall indemnify and defend
Landlord against and hold Landlord harmless from all claims, demands,
liabilities, damages, fines, encumbrances, liens, losses, costs and expenses,
including reasonable attorneys' fees and disbursements, and costs and expenses
of investigation, arising from or related to the existence on or after the
Commencement Date of Hazardous Material brought in or on the Property by Tenant
or the actual or threatened migration on or after the Commencement Date of
Hazardous Material from the Property as a result of contamination caused by
Tenant or the existence on or after the Commencement Date of a violation of
Environmental Requirements by Tenant with respect to the Property.
Notwithstanding the foregoing, Tenant shall not be required to indemnify, defend
or hold harmless Landlord with respect to Hazardous Materials brought or
migrating onto the Property or for violations of Environmental Requirements with
respect to the Property, unless Tenant is responsible for bringing the Hazardous
Materials onto the Property, for causing the migration or for the violation of
Environmental Requirements. To the extent Tenant has an indemnification
obligation under this Section 20.5, Tenant shall, to the reasonable satisfaction
of Landlord, perform all remedial actions necessary to remove any Hazardous
Material in or on the Property on or after the Commencement Date or to remedy
the actual or threatened migration from the Property of any Hazardous Material
or to remedy any actual or threatened violation of Environmental Requirements,
provided such remedial action is required under Environmental Requirements. This
Section 20.5 shall survive termination of this Lease.
20.6 LANDLORD INDEMNIFICATION. Landlord shall indemnify and defend
Tenant against and hold Tenant harmless from all claims, demands, liabilities,
damages, fines, encumbrances, liens, losses, costs and expenses, including
reasonable attorneys' fees and disbursements, and costs and expenses of
investigation, arising from or related to the existence prior to the
Commencement Date of Hazardous Materials brought in, on or, under the Property
by Landlord or the actual or threatened migration prior to the Commencement Date
of Hazardous Materials from the Property as a result of contamination caused by
Landlord or the existence prior to the Commencement Date of a violation of
Environmental Requirements by Landlord with respect to the Property.
- 28 -
Notwithstanding the foregoing, Landlord shall not be required to indemnify,
defend or hold harmless Tenant with respect Hazardous Materials brought or
migrating onto the Property or for violations of Environmental Requirements with
respect to the Property, unless Landlord is responsible for bringing the
Hazardous Materials on to the Property, for causing the migration or for the
violation of Environmental Requirements. To the extent Landlord has an
indemnification obligation under this Section 20.6, Landlord shall, to the
reasonable satisfaction of Tenant, perform all remedial actions necessary to
remove any Hazardous Material in or on the Property or to remedy actual or
threatened violation of Environmental Requirements, provided such remedial
action is required under Environmental Requirements. This Section 20.6 shall
survive termination of this Lease.
20.7 PERMITTED ACTIVITIES. Notwithstanding the foregoing, Landlord
acknowledges and agrees that Tenant shall be permitted to store and use on the
Premises from time to time certain Hazardous Material whose nature and
quantities are customary in connection with the permitted uses of the Premises
(and in connection with any permitted Alterations performed by Tenant), and that
Tenant shall not be required to provide Landlord with specific notice of any
storage or use; provided that Tenant shall at all times comply with all
Environmental Requirements pertaining to any such Hazardous Material.
ARTICLE 21
FAIR MARKET RENTAL RATE
21.1 DETERMINATION OF FAIR MARKET RENTAL RATE. For the proposes of the
Lease the term "Fair Market Rental Rate" shall mean the annual amount per
rentable square foot that is in effect for comparable period of time
("Comparable Transactions") at the Property, or if there are not a sufficient
number of Comparable Transactions at the Property, what a comparable landlord of
a first-class industry facility with comparable vacancy factors would accept in
Comparable Transactions. In any determination of Comparable Transactions
appropriate consideration shall be given to the annual rental rates per rentable
square foot, the standard of measurement by which the rentable square footage is
measured, the type of escalation clause (e.g., whether increases in additional
rent are determined on a net or gross basis, and if gross, whether such
increases are determined according to a base year or a base dollar amount
expense stop), the extent of Tenant's liability under the Lease, abatement
provisions reflecting free rent and/or no rent during the period of construction
or subsequent to the commencement date as to the space in question, brokerage
commissions, if any, that would be payable by Landlord in similar transactions,
length of the Lease term, size and location of the premises being leased,
building standard work and/or tenant improvement allowances, if any, and other
generally applicable conditions of tenancy for such Comparable Transactions. The
intent is that Tenant shall obtain the same rent and other economic benefits
that Landlord would otherwise give in Comparable Transactions and that Landlord
will make and receive the same economic payments and concessions that Landlord
would otherwise make and receive in Comparable Transactions. If, for example,
after applying the criteria set forth above, Comparable Transactions provide a
new tenant with comparable space at Thirty-
- 29 -
Two and 00/100 Dollars ($32.00) per rentable square foot, with a current base
year, three (3) months at no rent to construct improvements, four (4) months'
free rent, Fifty and 00/100 Dollars ($50.00) per usable square foot tenant
improvement allowance, a brokerage commission of Fifty Thousand and 00/100
Dollars ($50,000.00), and certain other generally applicable economic terms, the
Fair Market Rental Rate for Tenant shall not be Thirty-Two and 00/100 Dollars
($32.00) per rentable square foot only, but shall be the equivalent of
Thirty-Two and 00/100 Dollars ($32.00) per rentable square foot, the same base
year, three (3) months at no rent to construct improvements or three (3) months'
additional free rent in lieu of such construction, an additional four (4)
months' free rent, Fifty and 00/100 Dollars ($50.00) per usable square foot
tenant improvement allowance or payment in lieu of such allowance, a payment to
Tenant's then broker of a Fifty Thousand and 00/100 Dollars ($50,000.00)
brokerage commission (or if Tenant is not then represented by a broker, Tenant
shall receive a rent credit on the amount of the brokerage commission that
Landlord would have otherwise been required to pay) and such other generally
applicable economic terms.
Landlord shall determine the Fair Market Rental Rate by using its good
faith judgment. Landlord shall provide written notice of such amount within
fifteen (15) days (but in no event later than twenty (20) days) after Tenant
provides the notice to Landlord exercising Tenant's extension option(s). Tenant
shall have thirty (30) days ("Tenant's Review Period") after receipt of
Landlord's notice of the new rental within which to accept such rental or to
reasonably object thereto in writing. In the event Tenant objects, Landlord and
Tenant shall attempt to agree upon such Fair Market Rental Rate, using their
best good faith efforts. If Landlord and Tenant fail to reach agreement within
fifteen (15) days following Tenant's Review Period ("Outside Agreement Date"),
then each party shall place in a separate sealed envelope their final proposal
as to Fair Market Rental Rate and such determination shall be submitted to
arbitration in accordance with subsections (a) through (e) below. Failure of
Tenant to so elect in writing within Tenant's Review Period shall conclusively
be deemed its disapproval of the Fair Market Rental Rate determined by Landlord.
In the event that Landlord fails to timely generate the initial written
notice of Landlord's opinion of the Fair Market Rental Rate that triggers the
negotiation period, then Tenant may commence such negotiations by providing the
initial notice, in which event Landlord shall have fifteen (15) days
"(Landlord's Review Period") after receipt of Tenant's notice of the new rental
within which to accept such rental. In the event Landlord fails to accept in
writing such rental proposed by Tenant, then such proposal shall be deemed
rejected, and Landlord and Tenant shall attempt to agree upon such Fair Market
Rental Rate, using their best good faith efforts. If Landlord and Tenant fail to
reach agreement within fifteen (15) days following Landlord's Review Period
(which shall be, in such event, the "Outside Agreement Date" in lieu of the
above definition of such date), then each party shall place in a separate sealed
envelope their final proposal as to Fair Market Rental Rate and determination
shall be submitted to arbitration in accordance with subsections (a) through (e)
below. Failure of Landlord to so elect in writing within Landlord's Review
Period shall conclusively be deemed its disapproval of the Fair Market Rental
Rate determined by Tenant.
- 30 -
If the final determination of the Fair Market Rental Rate has not been
made prior to the date on which Tenant's obligation to pay rent during the
renewal term commences, then, from such date until the date the final
determination is made ("Interim Period"), Tenant shall pay estimated rent for
the Premises at the rate applicable to the Premises during the month immediately
preceding such rent commencement date. Once the final determination of the Fair
Market Rental Rate has been made, if the rent payable by Tenant for the Premises
pursuant to the Fair Market Rental Rate exceeds the rent paid by Tenant during
the Interim Period, Tenant shall pay the excess to Landlord concurrently with
its next installment of Base Rent, and, if the rent paid by Tenant during the
Interim Period exceeds the rent payable by Tenant for the Premises pursuant to
the Fair Market Rental Rate, then Landlord shall credit the excess against the
Base Rent or additional rent next coming due under the Lease.
(a) Landlord and Tenant shall meet with each other within five (5)
business days of the Outside Agreement Date and exchange the sealed
envelopes and then open such envelopes in each other's presence. If
Landlord and Tenant do not mutually agree upon the Fair Market Rental
Rate within five (5) business days of the exchange and opening of
envelopes, then, within ten (10) business days of the exchange and
opening of envelopes Landlord and Tenant shall agree upon and jointly
appoint a single arbitrator who shall by profession be a real estate
lawyer or broker who shall have been active over the five (5) year
period ending on the date of such appointment in the leasing of
industrial properties in the vicinity of the Property. Neither Landlord
nor Tenant shall consult with such broker or lawyer as to his or her
opinion as to Fair Market Rental Rate prior to the appointment. The
determination of the arbitrator shall be limited solely to the issue of
whether Landlord's or Tenant's submitted Fair Market Rental Rate for
the Premises is the closest to the actual Fair Market Rental Rate for
the Premises as determined by the arbitrator, taking into account the
requirements of this Article 21. Such arbitrator may hold such hearings
and require such briefs as the arbitrator, in his or her sole
discretion, determines necessary. In addition, Landlord and Tenant may
submit to the arbitrator with a copy to the other party within five (5)
business days after the appointment of the arbitrator any market data
and additional information that such party deems relevant to the
determination of Fair Market Rental Rate ("FMRR Data") and the other
party may submit a reply in writing within five (5) business days after
receipt of such FMRR Data.
(b) The arbitrator shall, within thirty (30) days of his or her
appointment, reach a decision as to whether the parties shall use
Landlord's or Tenant's submitted Fair Market Rental Rate by choosing
the submitted Fair Market Rental Rate that is closest to the actual
Fair Market Rental for the Premises as determined by the arbitrator,
and shall notify the Landlord and Tenant of such decision.
(c) The decision of the arbitrator shall be binding upon Landlord and
Tenant, except as provided below.
- 31 -
(d) If Landlord and Tenant fail to agree upon and appoint an
arbitrator, then appointment of the arbitrator shall be made by the
Presiding Judge of the Maricopa County Superior Court, or if he or she
refuses to act, by any judge having jurisdiction over the parties.
(e) The cost of arbitration shall be paid by Landlord and Tenant
equally.
In the event that Tenant objects to the Fair Marker Rental Rate as
determined by the arbitration provision specified above, Tenant may elect to
rescind its extension option election notice at any time within sixty (60) days
following the establishment of the Fair Market Rental Rate as determined by such
arbitration. In the event Tenant elects to terminate the Lease, Tenant shall
reimburse Landlord for its reasonable attorneys' fees and reasonable costs
associated with such arbitration.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease
Agreement as of the date first hereinabove written.
OMB DEVELOPMENT I, L.L.C, RADYNE CORP.,
an Arizona limited liability company a New York corporation
By: /s/ Xxxxxx X. Xxxxxxx By: /s/ R.C. Fitting
--------------------------- ------------------
Its: Manager Its: President
- 32 -
