EX-10.15
4
ex10p15.htm
Exhibit 10.15
This document contains confidential information that has been omitted
and filed separately with the Securities and Exchange Commission.
Such information is noted by three asterisks, as follows “***.”
|
ASSISTANCE AGREEMENT
|
|
1. Award No.
DE-EE0002532
|
2. Modification No.
|
3. Effective Date
06/16/2010
|
4. CFDA No.
81.086
|
|
5. Awarded To
FUTUREFUEL CHEMICAL COMPANY
Attn: XXXX XXXXXX
P.O. BOX 2357
BATESVILLE AR 725032357
|
6. Sponsoring Office
U.S. DOE/NETL
Morgantown Campus
0000 Xxxxxxx Xxxxx Xxxx
XX Xxx 000
Xxxxxxxxxx XX 00000-0000
|
7. Period of Performance
06/16/2010
through
06/15/2013
|
|
8. Type of Agreement
T Grant
£ Cooperative Agreement
£ Other
|
9. Authority
31 USC 6304 – See Page 2
10 USC 2358
|
10. Purchase Request or Funding Document No.
10EE000649
|
|
11. Remittance Address
FUTUREFUEL CHEMICAL COMPANY
Attn: XXXX XXXXXX
P.O. BOX 2357
BATESVILLE AR 725032357
|
12. Total Amount
Govt. Share: $12,600,000.00
Cost Share: $12,600,000.00
Total: $25,200,000.00
|
13. Funds Obligated
This Action:
$12,595,762.00
Total:
$12,595,762.00
|
|
14. Principal Investigator
Xxxx XxXxxxxxx
Phone: 000-000-0000
|
15. Program Manager
Xxxx X. Xxxxxxxx
Phone: 000-000-0000
|
16. Administrator
U.S. DOE/NETL
Morgantown Campus
0000 Xxxxxxx Xxxxx Xxxx
XX Xxx 000
Xxxxxxxxxx XX 00000-0000
|
|
17. Submit Payment Requests To
OR for NETL (Morgantown)
U.S. Department of Energy
Oak Ridge Financial Service Center
X.X. Xxx 0000
Xxx Xxxxx XX 00000
|
18. Paying Office
OR for NETL (Morgantown)
U.S. Department of Energy
Oak Ridge Financial Service Center
X.X. Xxx 0000
Xxx Xxxxx XX 00000
|
19. Submit Reports To
See Attachment 3
Federal Assistance
Reporting Checklist
|
|
20. Accounting and Appropriation Data
SEE SCHEDULE
|
|
21. Research Title and/or Description of Project
RECOVERY ACT – ESTABLISH AND EXPAND COMMERCIAL PRODUCTION OF GRAPHITE ANODE MATERIALS FOR HIGH PERFORMANCE LITHIUM-ION BATTERIES
|
|
For the Recipient
|
For the United States of America
|
|
22. Signature of Person Authorized to Sign
|
25. Signature of Grants/Agreement Officer
Signature on File
|
|
23. Name and Title
|
24. Date Signed
|
26. Name of Office
Xxxxx X. Xxxxxxxxxx
|
27. Date Signed
06/16/2010
|
| | |
|
CONTINUATION SHEET
|
REFERENCE NO. OF DOCUMENT BEING CONTINUED
DE-EE0002532
|
PAGE OF
| |
|
2
|
23
| |
|
NAME OF OFFEROR OR CONTRACTOR
FUTUREFUEL CHEMICAL COMPANY
| |
|
ITEM NO.
(A)
|
SUPPLIES/SERVICES
(B)
|
QUANTITY
(C)
|
UNIT
(D)
|
UNIT PRICE
(E)
|
AMOUNT
(F)
| |
| |
DUNS Number: 613174684
Project Period: 6/16/2010 – 6/15/2013
Budget Period: 6/16/2010 – 6/15/2013
DOE AWARD ADMINISTRATOR
Xxxxxx Xxxxx, (000) 000-0000
Xxxxxx.Xxxxx@xxxx.xxx.xxx
RECIPIENT BUSINESS POINT OF CONTACT
Xxxx Xxxxxx (000) 000-0000
XxxxXxxxxx@xxxxxxx.xxx
XXXXX 0 XXXXXXXXX
XX00-00 DOE Organization Act and PL111-5 American Recovery and Reinvestment Act of 2009 and PL109-58 Energy Policy Xxx 0000
ASAP: NO Extent Competed: COMPETED Xxxxx-Xxxxx
Act: YES
Fund: 05799 Appr Year: 2009 Allottee: 31 Report
Entity: 220520 Object Class: 25500 Program:
1005107 Project: 2004490 WFO: 0000000 Local Use:
0000000 TAS Agency: 89 TAS Account: 0331
| | | | | |
| | | | | |
JULY 2004
| |
| | |
|
SPECIAL TERMS AND CONDITIONS FOR USE IN MOST GRANTS AND COOPERATIVE AGREEMENTS
|
4
|
|
RESOLUTION OF CONFLICTING CONDITIONS
|
4
|
|
AWARD AGREEMENT TERMS AND CONDITIONS
|
4
|
|
CONDITIONS ON AWARD
|
4
|
|
PAYMENT PROCEDURES – REIMBURSEMENT THROUGH THE AUTOMATED CLEARING HOUSE (ACH) VENDER INQUIRY PAYMENT ELECTRONIC REPORTING SYSTEM (VIPERS)
|
5
|
|
COST SHARING FFRDC’S NOT INVOLVED
|
6
|
|
REBUDGETING AND RECOVERY OF INDIRECT COSTS – INDIRECT COSTS AND FRINGE BENEFITS ARE NOT REIMBURSABLE
|
7
|
|
USE OF PROGRAM INCOME - COST SHARING
|
7
|
|
FINAL INCURRED COST AUDIT
|
7
|
|
STATEMENT OF FEDERAL STEWARDSHIP
|
7
|
|
SITE VISITS
|
7
|
|
REPORTING REQUIREMENTS
|
7
|
|
PUBLICATIONS
|
8
|
|
FEDERAL, STATE, AND MUNICIPAL REQUIREMENTS
|
8
|
|
INTELLECTUAL PROPERTY PROVISIONS AND CONTACT INFORMATION
|
8
|
|
LOBBYING RESTRICTIONS
|
8
|
|
NOTICE REGARDING THE PURCHASE OF AMERICAN-MADE EQUIPMENT AND PRODUCTS — SENSE OF CONGRESS
|
9
|
|
PROPERTY
|
9
|
|
INSOLVENCY, BANKRUPTCY OR RECEIVERSHIP
|
9
|
|
NATIONAL ENVIRONMENTAL POLICY ACT (NEPA) REQUIREMENTS
|
10
|
|
INDEMNITY
|
10
|
|
DECONTAMINATION AND/OR DECOMMISSIONING (D &D) COSTS
|
11
|
|
SPECIAL PROVISIONS RELATING TO WORK FUNDED UNDER AMERICAN RECOVERY AND REINVESTMENT ACT OF 2009 (MAR 2009)
|
11
|
|
REPORTING AND REGISTRATION REQUIREMENTS UNDER SECTION 1512 OF THE RECOVERY ACT
|
14
|
|
WAGE RATE REQUIREMENTS UNDER SECTION 1606 OF THE RECOVERY ACT
|
14
|
|
RECOVERY ACT TRANSACTIONS LISTED IN SCHEDULE OF EXPENDITURES OF FEDERAL AWARDS AND RECIPIENT RESPONSIBILITIES FOR INFORMING SUBRECIPIENTS
|
15
|
|
XXXXX BACON ACT AND CONTRACT WORK HOURS AND SAFETY STANDARDS ACT
|
15
|
|
RECIPIENT FUNCTIONS
|
23
|
DE-EE0002532 Page 3 of 23
SPECIAL TERMS AND CONDITIONS FOR USE IN MOST GRANTS AND COOPERATIVE
AGREEMENTS
RESOLUTION OF CONFLICTING CONDITIONS
Any apparent inconsistency between Federal statutes and regulations and the terms and conditions contained in this award must be referred to the DOE Award Administrator for guidance.
AWARD AGREEMENT TERMS AND CONDITIONS
This award/agreement consists of the Grant and Cooperative Agreement cover page, plus the following:
a. Special terms and conditions.
b. Attachments:
Attachment No. Title
1 Intellectual Property Provisions
2 Statement of Project Objectives
3 Federal Assistance Reporting Checklist
4 Budget Pages
5 Wage Determination
c. Applicable program regulations: NONE
x. XXX Assistance Regulations, 10 CFR 600 at xxxx://xxxx.xxxxxxxxx.xxx.
e. If the award is for research and to a university or non-profit, the Research Terms & Conditions and the DOE Agency Specific Requirements at xxxx://xxx.xxx.xxx/xxx/xxxx/xxxxxx/xxx/xxxxx.xxx.
f. Application/proposal as approved by DOE.
g. National Policy Assurances to Be Incorporated as Award Terms in effect on date of award at xxxx://xxxxxxxxxx.xxxxxx.xxx/xxxxxxxx_xxx/0000.xxx.
CONDITIONS ON AWARD
1. Limitations Based upon National Environmental Policy Act (NEPA) Requirements
As stated in the “National Environmental Policy Act (NEPA) Requirements” provision of this award, the Recipient is restricted from taking any action using Federal funds that would have an adverse effect on the environment or limit the choice of reasonable alternatives prior to DOE issuing a Finding of No Significant Impact (FONSI) for projects requiring an environmental assessment or a Record of Decision (ROD) for projects requiring an environmental impact statement. In addition, the provision states that until DOE issues either a FONSI or a ROD for this project, the maximum DOE liability to the Recipient is DOE’s share of incurred costs up to $1,260,000, provided such costs are reasonable, allocable to the award, and allowable under the terms of the award and the applicable Federal cost principles. Please review the full text of the “National Environmental Policy Act (NEPA) Requirements” provision to ensure full compliance with the requirements of the provision.
2. Verification of Recipient’s Cost-Share
In addition to and pending resolution of the NEPA requirements for this award, summarized above, there is an additional limitation on the funding provided under this award pending verification of the Recipient’s proposed cost-share. DOE has obligated $12,595,762 for completion of the Project authorized by this agreement; however, only $11,559,819 will be available for reimbursement until the Recipient provides evidence of firm financial commitments for the $1,040,181 balance of the private sector share of the project cost as set forth below.
Not later than six (6) months after the effective date of the award or at such other time as may be mutually agreed, the Recipient shall provide to DOE firm commitments for the remaining balance of
DE-EE0002532 Page 4 of 23
the full private sector share of the project cost. Such evidence may include executed loans, bond financing agreements, state or local grants, third party contribution agreements, and/or additional direct costs on the project.
In the event DOE determines that the information provided by the Recipient is inadequate to assure the availability of full funding for the private sector share of the project cost, DOE reserves the right, at DOE’s discretion, to: (1) stop payment, (2) renegotiate the project scope and/or payment schedule, or (3) after the Recipient is provided 30 days advance written notice and opportunity to cure, declare the grant terminated by mutual agreement. Should DOE declare the grant terminated, the Recipient shall be entitled to payment of DOE’s share of allowable project cost incurred prior to the date of termination plus the reasonable cost of terminating contracts not to exceed $11,559,819.
Please note that the $11,559,819 funding limitation placed upon the Recipient by way of this condition is superseded by the $1,260,000 funding limitation applied by way of the “National Environmental Policy Act (NEPA) Requirements” provision of this award, summarized above. Upon the issuance of a FONSI or a ROD for this project, and the subsequent deletion of the NEPA condition by way of an amendment to this award, the $1,260,000 funding limitation is lifted, but the $11,559,819 funding limitation applied by way of this Cost-Share condition remains in effect.
3. Negotiation of Final Agreement between *** and FutureFuel
The work to be performed under this award, as detailed in the Statement of Project Objectives, is dependent upon the provision of proprietary information from *** to FutureFuel as detailed in their agreement dated ***. The two organizations have also signed a letter of intent dated *** in which they agree to develop a separate agreement by which FutureFuel will toll process a carbon powder to meet the specifications of ***. However, as of the date of award of this grant, the terms of the agreement between *** and FutureFuel have not been finalized and the formalized contractual vehicle has not been signed.
Not later than six (6) months after the effective date of the award or at such other time as may be mutually agreed, the Recipient shall provide to DOE the finalized signed agreement between *** and FutureFuel which executes the terms that were outlined in the Letter of Intent. DOE will review this agreement to ensure that it is compliant with the terms and conditions of the award.
In the event the Recipient does not provide the finalized signed agreement within six (6) months after the effective date of the award, or if the DOE determines that the agreement provided by the Recipient is not in compliance with the terms and conditions of the award, DOE reserves the right, at DOE’s discretion, to: (1) stop payment, (2) renegotiate the project scope and/or payment schedule, or (3) after the Recipient is provided 30 days advance written notice and opportunity to cure, declare the grant terminated by mutual agreement. Should DOE declare the grant terminated, the Recipient shall be entitled to payment of DOE’s share of allowable project cost incurred prior to the date of termination plus the reasonable cost of terminating contracts not to exceed the $11,559,819 limitation applied via the Cost-Share condition.
PAYMENT PROCEDURES – REIMBURSEMENT THROUGH THE AUTOMATED CLEARING HOUSE (ACH) VENDER INQUIRY PAYMENT ELECTRONIC REPORTING SYSTEM (VIPERS)
a. Method of Payment. Payment will be made by reimbursement through ACH.
b. Requesting Reimbursement. Requests for reimbursements must be made electronically through Department of Energy’s Oak Ridge Financial Service Center (ORFSC) VIPERS. To access and use VIPERS, you must enroll at xxxxx://xxxxxx.xxx.xxx.xxx/xxxxxx.xxx. Detailed instructions on how to enroll are provided on the web site.
DE-EE0002532 Page 5 of 23
For non-construction awards, you must submit a Standard Form (SF) 270, “Request for Advance or Reimbursement” at xxxxx://xxxxxx.xxx.xxx.xxx/xxxxxx.xxx and attach a file containing appropriate supporting documentation. The file attachment must show the total federal share claimed on the SF 270, the non-federal share claimed for the billing period if cost sharing is required, and cumulative expenditures to date (both Federal and non-Federal) for each of the following categories: salaries/wages and fringe benefits; equipment; travel; participant/training support costs, if any; other direct costs, including subawards/contracts; and indirect costs. For construction awards, you must submit a SF 271, “Outlay Report and Request for Reimbursement for Construction Programs,” through VIPERS.
c. Timing of submittals. Submittal of the SF 270 or SF 271 should coincide with your normal billing pattern, but not more frequently than every two weeks. Requests for reimbursement must be limited to the amount of disbursements made during the billing period for the federal share of direct project costs and the proportionate share of any allowable indirect costs incurred during that billing period.
d. Adjusting payment requests for available cash. You must disburse any funds that are available from repayments to and interest earned on a revolving fund, program income, rebates, refunds, contract settlements, audit recoveries, credits, discounts, and interest earned on any of those funds before requesting additional cash payments from DOE.
e. Payments. The DOE approving official will approve the invoice as soon as practicable but not later than 30 days after your request is received, unless the billing is improper. Upon receipt of an invoice payment authorization from the DOE approving official, the ORFSC will disburse payment to you. You may check the status of your payments at the VIPER web site. All payments are made by electronic funds transfer to the bank account identified on the ACH Vendor/Miscellaneous Payment Enrollment Form (SF 3881) that you filed.
COST SHARING FFRDC’S NOT INVOLVED
|
a.
|
Total Estimated Project Cost is the sum of the Government share and Recipient share of the estimated project costs. The Recipient’s cost share must come from non-Federal sources unless otherwise allowed by law. By accepting federal funds under this award, you agree that you are liable for your percentage share of total allowable project costs, on a budget period basis, even if the project is terminated early or is not funded to its completion. This cost is shared as follows:
|
|
Budget
Period
No.
|
Budget
Period Start
|
Government Share $/%
|
Recipient Share $/%
|
Total Estimated Cost
|
|
1
|
6/16/2010
|
$12,600,000 / 50%
|
$12,600,000 / 50%
|
$25,200,000
|
|
Total Project
|
$12,600,000 / 50%
|
$12,600,000 / 50%
|
$25,200,000
|
|
b.
|
If you discover that you may be unable to provide cost sharing of at least the amount identified in paragraph a of this term, you should immediately provide written notification to the DOE Award Administrator indicating whether you will continue or phase out the project. If you plan to continue the project, the notification must describe how replacement cost sharing will be secured.
|
|
c.
|
You must maintain records of all project costs that you claim as cost sharing, including in-kind costs, as well as records of costs to be paid by DOE. Such records are subject to audit.
|
|
d.
|
Failure to provide the cost sharing required by this term may result in the subsequent recovery by DOE of some or all the funds provided under the award.
|
DE-EE0002532 Page 6 of 23
REBUDGETING AND RECOVERY OF INDIRECT COSTS – INDIRECT COSTS AND FRINGE BENEFITS ARE NOT REIMBURSABLE
The budget for this award does not include indirect costs or fringe benefits. Therefore, these expenses shall not be charged to nor reimbursement requested for this project nor shall the fringe and indirect costs from this project be allocated to any other federally sponsored project. In addition, indirect costs or fringe benefits shall not be counted as cost share unless approved by the Contracting Officer.
USE OF PROGRAM INCOME - COST SHARING
If you earn program income during the project period as a result of this award, you may use the program income to meet your cost sharing requirement.
FINAL INCURRED COST AUDIT
In accordance with 10 CFR 600, DOE reserves the right to initiate a final incurred cost audit on this award. If the audit has not been performed or completed prior to the closeout of the award, DOE retains the right to recover an appropriate amount after fully considering the recommendations on disallowed costs resulting from the final audit.
STATEMENT OF FEDERAL STEWARDSHIP
DOE will exercise normal Federal stewardship in overseeing the project activities performed under this award. Stewardship activities include, but are not limited to, conducting site visits; reviewing performance and financial reports; providing technical assistance and/or temporary intervention in unusual circumstances to correct deficiencies which develop during the project; assuring compliance with terms and conditions; and reviewing technical performance after project completion to ensure that the award objectives have been accomplished.
SITE VISITS
DOE’s authorized representatives have the right to make site visits at reasonable times to review project accomplishments and management control systems and to provide technical assistance, if required. You must provide, and must require your subrecipients to provide, reasonable access to facilities, office space, resources, and assistance for the safety and convenience of the government representatives in the performance of their duties. All site visits and evaluations must be performed in a manner that does not unduly interfere with or delay the work.
REPORTING REQUIREMENTS
a. Requirements. The reporting requirements for this award are identified on the Federal Assistance Reporting Checklist, DOE F 4600.2, attached to this award. Failure to comply with these reporting requirements is considered a material noncompliance with the terms of the award. Noncompliance may result in withholding of future payments, suspension, or termination of the current award, and withholding of future awards. A willful failure to perform, a history of failure to perform, or unsatisfactory performance of this and/or other financial assistance awards, may also result in a debarment action to preclude future awards by Federal agencies.
b. Dissemination of scientific/technical reports. Scientific/technical reports submitted under this award will be disseminated on the Internet via the DOE Information Bridge (xxx.xxxx.xxx/xxxxxx), unless the report contains patentable material, protected data, or SBIR/STTR data. Citations for journal articles
7E-EE0002532 Page 7 of 23
produced under the award will appear on the DOE Energy Citations Database (xxx.xxxx.xxx/xxxxxxxxxxxxxxx).
c. Restrictions. Reports submitted to the DOE Information Bridge must not contain any Protected Personal Identifiable Information (PII), limited rights data (proprietary data), classified information, information subject to export control classification, or other information not subject to release.
NOTE: Subject to OMB approval pursuant to the Paperwork Reduction Act, DOE reserves the right to amend the reporting requirements to request more frequent and more detailed reporting.
PUBLICATIONS
a. You are encouraged to publish or otherwise make publicly available the results of the work conducted under the award.
b. An acknowledgment of Federal support and a disclaimer must appear in the publication of any material, whether copyrighted or not, based on or developed under this project, as follows:
Acknowledgment: “This material is based upon work supported by the Department of Energy under Award Number DE-EE0002532.”
Disclaimer: “This report was prepared as an account of work sponsored by an agency of the United States Government. Neither the United States Government nor any agency thereof, nor any of their employees, makes any warranty, express or implied, or assumes any legal liability or responsibility for the accuracy, completeness, or usefulness of any information, apparatus, product, or process disclosed, or represents that its use would not infringe privately owned rights. Reference herein to any specific commercial product, process, or service by trade name, trademark, manufacturer, or otherwise does not necessarily constitute or imply its endorsement, recommendation, or favoring by the United States Government or any agency thereof. The views and opinions of authors expressed herein do not necessarily state or reflect those of the United States Government or any agency thereof.”
FEDERAL, STATE, AND MUNICIPAL REQUIREMENTS
You must obtain any required permits and comply with applicable federal, state, and municipal laws, codes, and regulations for work performed under this award.
INTELLECTUAL PROPERTY PROVISIONS AND CONTACT INFORMATION
a. The intellectual property provisions applicable to this award are provided as an attachment to this award or are referenced on the Assistance Agreement Face Page. A list of all intellectual property provisions may be found at xxxx://xxx.xx.xxx.xxx/xxxxxxxxx_xxxxxxxxxx_xxxxxx.xxx.
b. Questions regarding intellectual property matters should be referred to the DOE Award Administrator and the Patent Counsel designated as the service provider for the DOE office that issued the award. The IP Service Providers List is found at
xxxx://xxx.xx.xxx.xxx/xxxxxxxxx/Xxxxxxxxxxxx_Xxxxxxxx_(XX)_Xxxxxxx_Xxxxxxxxx_xxx_Xxxxxxxxxxx.xxx.
LOBBYING RESTRICTIONS
By accepting funds under this award, you agree that none of the funds obligated on the award shall be expended, directly or indirectly, to influence congressional action on any legislation or appropriation matters pending before Congress, other than to communicate to Members of Congress as described in 18
DE-EE0002532 Page 8 of 23
U.S.C. 1913. This restriction is in addition to those prescribed elsewhere in statute and regulation.
NOTICE REGARDING THE PURCHASE OF AMERICAN-MADE EQUIPMENT AND PRODUCTS — SENSE OF CONGRESS
It is the sense of the Congress that, to the greatest extent practicable, all equipment and products purchased with funds made available under this award should be American-made.
PROPERTY
Real property, and equipment acquired by the Recipient shall be subject to the rules set forth in 10 CFR 600.130-137, 10 CFR 600.231-233, or 10 CFR 600.320-324 as applicable.
Consistent with the goals and objectives of this project, the Recipient may continue to use Recipient acquired property beyond the Period of Performance, without obligation, during the period of such use, to extinguish DOE’s conditional title to such property as described in 10 CFR 600.132-135, 10 CFR 600.231-233, 600.321-324, subject to the following: (a) the Recipient continues to utilize such property for the objectives of the project as set forth in the Statement of Project Objectives; (b) DOE retains the right to periodically ask for, and the Recipient agrees to provide, reasonable information concerning the use and condition of the property; and (c) the Recipient follows the property disposition rules set forth in the applicable sections of 10 CFR Part 600, if the property is no longer used by the Recipient for the objectives of the project, and the fair market value of property exceeds $5,000.
Once the per unit fair market value of the property is less than $5,000, pursuant to the applicable sections of 10 CFR Part 600, DOE’s residual interest in the property shall be extinguished and Recipient shall have no further obligation to the DOE with respect to the property.
The regulations as set forth in 10 CFR Part 600 and the requirements of this article shall also apply to property in the possession of any team member, sub-recipient or other entity where such property was acquired in whole in part with funds provided by DOE under this grant or where such property was counted as cost-sharing under the grant.
INSOLVENCY, BANKRUPTCY OR RECEIVERSHIP
a. You shall immediately notify the DOE of the occurrence of any of the following events: (i) you or your parent’s filing of a voluntary case seeking liquidation or reorganization under the Bankruptcy Act; (ii) your consent to the institution of an involuntary case under the Bankruptcy Act against you or your parent; (iii) the filing of any similar proceeding for or against you or your parent, or its consent to, the dissolution, winding-up or readjustment of your debts, appointment of a receiver, conservator, trustee, or other officer with similar powers over you, under any other applicable state or federal law; or (iv) your insolvency due to your inability to pay your debts generally as they become due.
b. Such notification shall be in writing and shall: (i) specifically set out the details of the occurrence of an event referenced in paragraph a; (ii) provide the facts surrounding that event; and (iii) provide the impact such event will have on the project being funded by this award.
c. Upon the occurrence of any of the four events described in the first paragraph, DOE reserves the right to conduct a review of your award to determine your compliance with the required elements of the award (including such items as cost share, progress towards technical project objectives, and submission of required reports). If the DOE review determines that there are significant deficiencies or concerns with your performance under the award, DOE reserves the right to impose additional requirements, as needed, including (i) change your payment method; or (ii) institute payment controls.
DE-EE0002532 Page 9 of 23
d. Failure of the Recipient to comply with this term may be considered a material noncompliance of this financial assistance award by the Contracting Officer.
NATIONAL ENVIRONMENTAL POLICY ACT (NEPA) REQUIREMENTS
You are prohibited from taking any action using Federal funds that would have an adverse effect on the environment or limit the choice of reasonable alternatives prior to DOE issuing a Finding of No Significant Impact (FONSI) for projects requiring an environmental assessment or a Record of Decision (ROD) for projects requiring an environmental impact statement. Prohibited actions include, but are not limited to, purchase of long-lead time equipment; demolition or decontamination of existing buildings; site preparation, clearing, ground breaking, excavation, and construction; and detailed design. However, activities necessary to perform site characterization, sampling, or monitoring; preparation of conceptual design data, analysis, documentation (including project planning assistance); and training may be performed before a FONSI or ROD is issued.
In the event you elect to proceed with activities that could have an adverse impact on the environment prior to DOE issuing a FONSI or a ROD, you acknowledge that such activities are at your risk in that the DOE may not reimburse you for these costs depending on the outcome of the NEPA process.
Prior to the issuance of a FONSI or ROD, DOE agrees to discuss with you any proposed conditions and requirements that may be included in it if DOE decides to proceed with its proposed action. However, DOE retains sole discretion on whether to issue a FONSI or ROD and what conditions and requirements to include in it if one is issued.
If DOE decides to proceed with its proposed action subject to conditions, limitations, mitigation requirements, or monitoring requirements specified in a FONSI or ROD, you agree to:
a) abide by the conditions, limitations, mitigation requirements, and monitoring requirements specified in the FONSI or ROD;
b) negotiate changes to the project schedule, costs, and/or scope as necessary to effect the requirements or conditions in the FONSI or ROD;
c) allow DOE’s authorized representatives to visit the site and facilities upon notice to verify project status and compliance to include conditions and requirements in the FONSI or ROD; and
d) submit data or otherwise meet specified reporting requirements that may be in the FONSI or ROD.
If the Recipient finds the conditions and requirements to be unacceptable, the Recipient reserves the right to terminate the award in accordance with 10 CFR 600.161(a)(3), 244(b), 351(a)(3), as applicable and DOE will deobligate any remaining funds.
In the event DOE does not issue a NEPA determination supporting the project or the Recipient withdraws from the project as a result of mitigation requirements contained in DOE’s NEPA determination, the maximum DOE liability to the Recipient is DOE’s share of incurred costs up to $1,260,000, provided such costs are reasonable, allocable to the award, and allowable under the terms of the award and the applicable Federal cost principles. DOE reserves the right to unilaterally deobligate the balance of funds obligated, but not authorized for expenditure, in the event the foregoing NEPA requirements are not satisfied.
INDEMNITY
The Recipient shall indemnify the Government and its officers, agents, or employees for any and all liability, including litigation expenses and attorneys’ fees, arising from suits, actions, or claims of any
DE-EE0002532 Page 10 of 23
character for death, bodily injury, or loss of or damage to property or to the environment, resulting from the project, except to the extent that such liability results from the direct fault or negligence of Government officers, agents or employees, or to the extent such liability may be covered by applicable allowable costs provisions.
DECONTAMINATION AND/OR DECOMMISSIONING (D &D) COSTS
Notwithstanding any other terms of this Agreement, the Government shall not be responsible for or have any obligation to the recipient for (i) Decontamination and/or Decommissioning (D&D) of any of the recipient’s facilities, or (ii) any costs which may be incurred by the recipient in connection with the D&D of any of its facilities due to the performance of the work under this Agreement, whether said work was performed prior to or subsequent to the effective date of this Agreement.
SPECIAL PROVISIONS RELATING TO WORK FUNDED UNDER AMERICAN RECOVERY AND REINVESTMENT ACT OF 2009 (MAR 2009)
Preamble
The American Recovery and Reinvestment Act of 2009, Pub., L. 111-5, (Recovery Act) was enacted to preserve and create jobs and promote economic recovery, assist those most impacted by the recession, provide investments needed to increase economic efficiency by spurring technological advances in science and health, invest in transportation, environmental protection, and other infrastructure that will provide long-term economic benefits, stabilize State and local government budgets, in order to minimize and avoid reductions in essential services and counterproductive State and local tax increases. Recipients shall use grant funds in a manner that maximizes job creation and economic benefit.
The Recipient shall comply with all terms and conditions in the Recovery Act relating generally to governance, accountability, transparency, data collection and resources as specified in Act itself and as discussed below.
Recipients should begin planning activities for their first tier subrecipients, including obtaining a DUNS number (or updating the existing DUNS record), and registering with the Central Contractor Registration (CCR).
Be advised that Recovery Act funds can be used in conjunction with other funding as necessary to complete projects, but tracking and reporting must be separate to meet the reporting requirements of the Recovery Act and related guidance. For projects funded by sources other than the Recovery Act, Contractors must keep separate records for Recovery Act funds and to ensure those records comply with the requirements of the Act.
The Government has not fully developed the implementing instructions of the Recovery Act, particularly concerning specific procedural requirements for the new reporting requirements. The Recipient will be provided these details as they become available. The Recipient must comply with all requirements of the Act. If the recipient believes there is any inconsistency between ARRA requirements and current award terms and conditions, the issues will be referred to the Contracting Officer for reconciliation.
Definitions
For purposes of this term, Covered Funds means funds expended or obligated from appropriations under the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5. Covered Funds will have special accounting codes and will be identified as Recovery Act funds in the grant, cooperative agreement or TIA and/or modification using Recovery Act funds. Covered Funds must be reimbursed by September 30, 2015.
DE-EE0002532 Page 11 of 23
Non-Federal employer means any employer with respect to covered funds – the contractor, subcontractor, grantee, or recipient, as the case may be, if the contractor, subcontractor, grantee, or recipient is an employer; and any professional membership organization, certification of other professional body, any agent or licensee of the Federal government, or any person acting directly or indirectly in the interest of an employer receiving covered funds; or with respect to covered funds received by a State or local government, the State or local government receiving the funds and any contractor or subcontractor receiving the funds and any contractor or subcontractor of the State or local government; and does not mean any department, agency, or other entity of the federal government.
Recipient means any entity that receives Recovery Act funds directly from the Federal government (including Recovery Act funds received through grant, loan, or contract) other than an individual and includes a State that receives Recovery Act Funds.
Special Provisions
Recipients must include these special terms and conditions in any subaward.
Recipients must segregate the obligations and expenditures related to funding under the Recovery Act. Financial and accounting systems should be revised as necessary to segregate, track and maintain these funds apart and separate from other revenue streams. No part of the funds from the Recovery Act shall be commingled with any other funds or used for a purpose other than that of making payments for costs allowable for Recovery Act projects.
|
C.
|
Prohibition on Use of Funds
|
None of the funds provided under this agreement derived from the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5, may be used by any State or local government, or any private entity, for any casino or other gambling establishment, aquarium, zoo, golf course, or swimming pool.
With respect to each financial assistance agreement awarded utilizing at least some of the funds appropriated or otherwise made available by the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5, any representative of an appropriate inspector general appointed under section 3 or 8G of the Inspector General Act of 1988 (5 U.S.C. App.) or of the Comptroller General is authorized --
(1) to examine any records of the contractor or grantee, any of its subcontractors or subgrantees, or any State or local agency administering such contract that pertain to, and involve transactions that relate to, the subcontract, subcontract, grant, or subgrant; and
(2) to interview any officer or employee of the contractor, grantee, subgrantee, or agency regarding such transactions.
An application may contain technical data and other data, including trade secrets and/or privileged or confidential information, which the applicant does not want disclosed to the public or used by the Government for any purpose other than the application. To protect such data, the applicant should specifically identify each page including each line or paragraph thereof containing the data to be protected and xxxx the cover sheet of the application with the following Notice as well as referring to the Notice on each page to which the Notice applies:
Notice of Restriction on Disclosure and Use of Data
The data contained in pages ---- of this application have been submitted in confidence and contain trade
DE-EE0002532 Page 12 of 23
secrets or proprietary information, and such data shall be used or disclosed only for evaluation purposes, provided that if this applicant receives an award as a result of or in connection with the submission of this application, DOE shall have the right to use or disclose the data here to the extent provided in the award. This restriction does not limit the Government’s right to use or disclose data obtained without restriction from any source, including the applicant.
Information about this agreement will be published on the Internet and linked to the website
xxx.xxxxxxxx.xxx, maintained by the Accountability and Transparency Board. The Board may exclude posting contractual or other information on the website on a case-by-case basis when necessary to protect national security or to protect information that is not subject to disclosure under sections 552 and 552a of title 5, United States Code.
|
F.
|
Protecting State and Local Government and Contractor Whistleblowers.
|
The requirements of Section 1553 of the Act are summarized below. They include, but are not limited to:
Prohibition on Reprisals: An employee of any non-Federal employer receiving covered funds under the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5, may not be discharged, demoted, or otherwise discriminated against as a reprisal for disclosing, including a disclosure made in the ordinary course of an employees duties, to the Accountability and Transparency Board, an inspector general, the Comptroller General, a member of Congress, a State or Federal regulatory or law enforcement agency, a person with supervisory authority over the employee (or other person working for the employer who has the authority to investigate, discover or terminate misconduct), a court or grand jury, the head of a Federal agency, or their representatives information that the employee believes is evidence of:
- gross mismanagement of an agency contract or grant relating to covered funds;
- a gross waste of covered funds;
- a substantial and specific danger to public health or safety related to the implementation or use of covered funds;
- an abuse of authority related to the implementation or use of covered funds; or
- as violation of law, rule, or regulation related to an agency contract (including the competition for or negotiation of a contract) or grant, awarded or issued relating to covered funds.
Agency Action: Not later than 30 days after receiving an inspector general report of an alleged reprisal, the head of the agency shall determine whether there is sufficient basis to conclude that the non-Federal employer has subjected the employee to a prohibited reprisal. The agency shall either issue an order denying relief in whole or in part or shall take one or more of the following actions:
- Order the employer to take affirmative action to xxxxx the reprisal.
- Order the employer to reinstate the person to the position that the person held before the reprisal, together with compensation including back pay, compensatory damages, employment benefits, and other terms and conditions of employment that would apply to the person in that position if the reprisal had not been taken.
- Order the employer to pay the employee an amount equal to the aggregate amount of all costs and expenses (including attorneys’ fees and expert witnesses’ fees) that were reasonably incurred by the employee for or in connection with, bringing the complaint regarding the reprisal, as determined by the head of a court of competent jurisdiction.
Nonenforceability of Certain Provisions Waiving Rights and remedies or Requiring Arbitration: Except as provided in a collective bargaining agreement, the rights and remedies provided to aggrieved employees by this section may not be waived by any agreement, policy, form, or condition of employment, including any predispute arbitration agreement. No predispute arbitration agreement shall be valid or enforceable if it requires arbitration of a dispute arising out of this section.
Requirement to Post Notice of Rights and Remedies: Any employer receiving covered funds under the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5, shall post notice of the rights and remedies as required therein. (Refer to section 1553 of the American Recovery and Reinvestment Act of 2009, Pub. L. 111-5, xxx.Xxxxxxxx.xxx, for specific requirements of this section and prescribed language
DE-EE0002532 Page 13 of 23
for the notices.).
Recipient and sub-recipients shall promptly refer to the DOE or other appropriate Inspector General any credible evidence that a principal, employee, agent, contractor, sub-grantee, subcontractor or other person has submitted a false claim under the False Claims Act or has committed a criminal or civil violation of laws pertaining to fraud, conflict of interest, bribery, gratuity or similar misconduct involving those funds.
|
I.
|
Information in Support of Recovery Act Reporting
|
Recipient may be required to submit backup documentation for expenditures of funds under the Recovery Act including such items as timecards and invoices. Recipient shall provide copies of backup documentation at the request of the Contracting Officer or designee.
Funds appropriated under the Recovery Act and obligated to this award are available for reimbursement of costs until September 30, 2015.
REPORTING AND REGISTRATION REQUIREMENTS UNDER SECTION 1512 OF THE RECOVERY ACT
(a) This award requires the recipient to complete projects or activities which are funded under the American Recovery and Reinvestment Act of 2009 (Recovery Act) and to report on use of Recovery Act funds provided through this award. Information from these reports will be made available to the public.
(b) The reports are due no later than ten calendar days after each calendar quarter in which the recipient receives the assistance award funded in whole or in part by the Recovery Act.
(c) Recipients and their first-tier recipients must maintain current registrations in the Central Contractor Registration (xxxx://xxx.xxx.xxx) at all times during which they have active federal awards funded with Recovery Act funds. A Dun and Bradstreet Data Universal Numbering System (DUNS) Number (xxxx://xxx.xxx.xxx) is one of the requirements for registration in the Central Contractor Registration.
(d) The recipient shall report the information described in section 1512(c) of the Recovery Act using the reporting instructions and data elements that will be provided online at xxxx://xxx.XxxxxxxXxxxxxxxx.xxx and ensure that any information that is pre-filled is corrected or updated as needed.
WAGE RATE REQUIREMENTS UNDER SECTION 1606 OF THE RECOVERY ACT
(a) Section 1606 of the Recovery Act requires that all laborers and mechanics employed by contractors and subcontractors on projects funded directly by or assisted in whole or in part by and through the Federal Government pursuant to the Recovery Act shall be paid wages at rates not less than those prevailing on projects of a character similar in the locality as determined by the Secretary of Labor in accordance with subchapter IV of chapter 31 of title 40, United States Code.
Pursuant to Reorganization Plan No. 14 and the Xxxxxxxx Act, 40 U.S.C. 3145, the Department of Labor has issued regulations at 29 CFR parts 1, 3, and 5 to implement the Xxxxx-Xxxxx and related Acts. Regulations in 29 CFR 5.5 instruct agencies concerning application of the standard Xxxxx-Xxxxx contract clauses set forth in that section. Federal agencies providing grants, cooperative agreements, and loans under the Recovery Act shall ensure that the standard Xxxxx-Xxxxx contract clauses found in 29 CFR 5.5(a) are
DE-EE0002532 Page 14 of 23
incorporated in any resultant covered contracts that are in excess of $2,000 for construction, alteration or repair (including painting and decorating).
(b) For additional guidance on the wage rate requirements of section 1606, contact your awarding agency. Recipients of grants, cooperative agreements and loans should direct their initial inquiries concerning the application of Xxxxx-Xxxxx requirements to a particular federally assisted project to the Federal agency funding the project. The Secretary of Labor retains final coverage authority under Reorganization Plan Number 14.
RECOVERY ACT TRANSACTIONS LISTED IN SCHEDULE OF EXPENDITURES OF FEDERAL AWARDS AND RECIPIENT RESPONSIBILITIES FOR INFORMING SUBRECIPIENTS
(a) To maximize the transparency and accountability of funds authorized under the American Recovery and Reinvestment Act of 2009 (Pub. L. 111--5) (Recovery Act) as required by Congress and in accordance with 2 CFR 215.21 “Uniform Administrative Requirements for Grants and Agreements” and OMB Circular A--102 Common Rules provisions, recipients agree to maintain records that identify adequately the source and application of Recovery Act funds. OMB Circular A--102 is available at xxxx://xxx.xxxxxxxxxx.xxx/xxx/xxxxxxxxx/x000/x000.xxxx.
(b) For recipients covered by the Single Audit Act Amendments of 1996 and OMB Circular A--133, “Audits of States, Local Governments, and Non-Profit Organizations,” recipients agree to separately identify the expenditures for Federal awards under the Recovery Act on the Schedule of Expenditures of Federal Awards (SEFA) and the Data Collection Form (SF--SAC) required by OMB Circular A--133. OMB Circular A--133 is available at xxxx://xxx.xxxxxxxxxx.xxx/xxx/xxxxxxxxx/x000/x000.xxxx. This shall be accomplished by identifying expenditures for Federal awards made under the Recovery Act separately on the SEFA, and as separate rows under Item 9 of Part III on the SF--SAC by CFDA number, and inclusion of the prefix “ARRA-” in identifying the name of the Federal program on the SEFA and as the first characters in Item 9d of Part III on the SF--SAC.
(c) Recipients agree to separately identify to each subrecipient, and document at the time of subaward and at the time of disbursement of funds, the Federal award number, CFDA number, and amount of Recovery Act funds. When a recipient awards Recovery Act funds for an existing program, the information furnished to subrecipients shall distinguish the subawards of incremental Recovery Act funds from regular subawards under the existing program.
(d) Recipients agree to require their subrecipients to include on their SEFA information to specifically identify Recovery Act funding similar to the requirements for the recipient SEFA described above. This information is needed to allow the recipient to properly monitor subrecipient expenditure of ARRA funds as well as oversight by the Federal awarding agencies, Offices of Inspector General and the Government Accountability Office.
XXXXX XXXXX ACT AND CONTRACT WORK HOURS AND SAFETY STANDARDS ACT
Definitions: For purposes of this article, Xxxxx Bacon Act and Contract Work Hours and Safety Standards Act, the following definitions are applicable:
(1) “Award” means any grant, cooperative agreement or technology investment agreement made with Recovery Act funds by the Department of Energy (DOE) to a Recipient. Such Award must require compliance with the labor standards clauses and wage rate requirements of the Xxxxx-Xxxxx Act (DBA) for work performed by all laborers and mechanics employed by Recipients (other than a unit of State or local government whose own employees perform the construction) Subrecipients, Contractors and subcontractors.
DE-EE0002532 Page 15 of 23
(2) “Contractor” means an entity that enters into a Contract. For purposes of these clauses, Contractor shall include (as applicable) prime contractors, Recipients, Subrecipients, and Recipients’ or Subrecipients’ contractors, subcontractors, and lower-tier subcontractors. “Contractor” does not mean a unit of State or local government where construction is performed by its own employees.”
(3) “Contract” means a contract executed by a Recipient, Subrecipient, prime contractor or any tier subcontractor for construction, alteration, or repair. It may also mean (as applicable) (i) financial assistance instruments such as grants, cooperative agreements, technology investment agreements, and loans; and, (ii) Sub awards, contracts and subcontracts issued under financial assistance agreements. “Contract” does not mean a financial assistance instrument with a unit of State or local government where construction is performed by its own employees.
(4) “Contracting Officer” means the DOE official authorized to execute an Award on behalf of DOE and who is responsible for the business management and non-program aspects of the financial assistance process.
(5) “Recipient” means any entity other than an individual that receives an Award of Federal funds in the form of a grant, cooperative agreement or technology investment agreement directly from the Federal Government and is financially accountable for the use of any DOE funds or property, and is legally responsible for carrying out the terms and conditions of the program and Award.
(6) “Subaward” means an award of financial assistance in the form of money, or property in lieu of money, made under an award by a Recipient to an eligible Subrecipient or by a Subrecipient to a lower- tier subrecipient. The term includes financial assistance when provided by any legal agreement, even if the agreement is called a contract, but does not include the Recipient’s procurement of goods and services to carry out the program nor does it include any form of assistance which is excluded from the definition of “Award” above.
(7) “Subrecipient” means a non-Federal entity that expends Federal funds received from a Recipient to carry out a Federal program, but does not include an individual that is a beneficiary of such a program.
(a) Xxxxx Xxxxx Act
(1) Minimum wages.
(i) All laborers and mechanics employed or working upon the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Xxxxxxxx Act (29 CFR part 3) ), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics.
Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Xxxxx-Xxxxx Act on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (a)(1)(iv) of this section; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such weekly period. Such laborers and mechanics shall be paid the appropriate
DE-EE0002532 Page 16 of 23
wage rate and fringe benefits on the wage determination for the classification of work actually performed, without regard to skill, except as provided in § 5.5(a)(4). Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein: Provided, That the employer’s payroll records accurately set forth the time spent in each classification in which work is performed. The wage determination (including any additional classification and wage rates conformed under paragraph (a)(1)(ii) of this section) and the Xxxxx-Xxxxx poster (WH-1321) shall be posted at all times by the Contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers.
(ii) (A) The Contracting Officer shall require that any class of laborers or mechanics, including helpers, which is not listed in the wage determination and which is to be employed under the Contract shall be classified in conformance with the wage determination. The Contracting Officer shall approve an additional classification and wage rate and, fringe benefits therefore only when the following criteria have been met:
(1) The work to be performed by the classification requested is not performed by a classification in the wage determination; and
(2) The classification is utilized in the area by the construction industry; and
(3) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination.
(B) If the Contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the Contracting Officer agree on the classification and wage rate (including the amount designated for fringe benefits where appropriate), a report of the action taken shall be sent by the Contracting Officer to the Administrator of the Wage and Hour Division, U.S. Department of Labor, Xxxxxxxxxx, XX 00000. The Administrator, or an authorized representative, will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.
(C) In the event the Contractor, the laborers or mechanics to be employed in the classification or their representatives, and the Contracting Officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the Contracting Officer shall refer the questions, including the views of all interested parties and the recommendation of the Contracting Officer, to the Administrator for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30- day period that additional time is necessary.
(D) The wage rate (including fringe benefits where appropriate) determined pursuant to paragraphs (a)(1)(ii)(B) or (C) of this section, shall be paid to all workers performing work in the classification under this Contract from the first day on which work is performed in the classification.
(iii) Whenever the minimum wage rate prescribed in the Contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof.
(iv) If the Contractor does not make payments to a trustee or other third person, the
DE-EE0002532 Page 17 of 23
Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided, That the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Xxxxx-Xxxxx Act have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.
(2) Withholding. The Department of Energy or the Recipient or Subrecipient shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld from the Contractor under this Contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to Xxxxx-Xxxxx prevailing wage requirements, which is held by the same prime contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full amount of wages required by the Contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the project), all or part of the wages required by the Contract, the Department of Energy, Recipient, or Subrecipient, may, after written notice to the Contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.
(3) Payrolls and basic records.
(i) Payrolls and basic records relating thereto shall be maintained by the Contractor during the course of the work and preserved for a period of three years thereafter for all laborers and mechanics working at the site of the work (or under the United States Housing Act of 1937, or under the Housing Act of 1949, in the construction or development of the project). Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in section 1(b)(2)(B) of the Xxxxx-Xxxxx Act), daily and weekly number of hours worked, deductions made and actual wages paid. Whenever the Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv) that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in section 1(b)(2)(B) of the Xxxxx-Xxxxx Act, the Contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.
(ii) (A) The Contractor shall submit weekly for each week in which any Contract work is performed a copy of all payrolls to the Department of Energy if the agency is a party to the Contract, but if the agency is not such a party, the Contractor will submit the payrolls to the Recipient or Subrecipient (as applicable), applicant, sponsor, or owner, as the case may be, for transmission to the Department of Energy. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under 29 CFR 5.5(a)(3)(i), except that full social security numbers and home addresses shall not be included on weekly transmittals. Instead the payrolls shall only need to include an individually identifying number for each employee (e.g., the last four digits of the employee’s social security number). The
DE-EE0002532 Page 18 of 23
required weekly payroll information may be submitted in any form desired. Optional Form WH-347 is available for this purpose from the Wage and Hour Division Web site at xxxx://xxx.xxx.xxx/xxx/xxx/xxxxx/xx000xxxxx.xxx or its successor site. The prime Contractor is responsible for the submission of copies of payrolls by all subcontractors. Contractors and subcontractors shall maintain the full social security number and current address of each covered worker, and shall provide them upon request to the Department of Energy if the agency is a party to the Contract, but if the agency is not such a party, the Contractor will submit them to the Recipient or Subrecipient (as applicable), applicant, sponsor, or owner, as the case may be, for transmission to the Department of Energy, the Contractor, or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a prime contractor to require a subcontractor to provide addresses and social security numbers to the prime contractor for its own records, without weekly submission to the sponsoring government agency (or the Recipient or Subrecipient (as applicable), applicant, sponsor, or owner).
(B) Each payroll submitted shall be accompanied by a “Statement of Compliance,” signed by the Contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the Contract and shall certify the following:
(1) That the payroll for the payroll period contains the information required to be provided under § 5.5 (a)(3)(ii) of Regulations, 29 CFR part 5, the appropriate information is being maintained under § 5.5 (a)(3)(i) of Regulations, 29 CFR part 5, and that such information is correct and complete;
(2) That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the Contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR part 3;
(3) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the Contract.
(C) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the “Statement of Compliance” required by paragraph (a)(3)(ii)(B) of this section.
(D) The falsification of any of the above certifications may subject the Contractor or subcontractor to civil or criminal prosecution under section 1001 of title 18 and section 3729 of title 31 of the United States Code.
(iii) The Contractor or subcontractor shall make the records required under paragraph (a)(3)(i) of this section available for inspection, copying, or transcription by authorized representatives of the Department of Energy or the Department of Labor, and shall permit such representatives to interview employees during working hours on the job. If the Contractor or subcontractor fails to submit the required records or to make them available, the Federal agency may, after written notice to the Contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for
DE-EE0002532 Page 19 of 23
debarment action pursuant to 29 CFR 5.12.
(4) Apprentices and trainees--
(i) Apprentices. Apprentices will be permitted to work at less than the predetermined rate for work they performed when they are employed pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer and Labor Services, or with a State Apprenticeship Agency recognized by the Office, or if a person is employed in his or her first 90 days of probationary employment as an apprentice in such an apprenticeship program, who is not individually registered in the program, but who has been certified by the Office of Apprenticeship Training, Employer and Labor Services or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the Contractor as to the entire work force under the registered program. Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated above, shall be paid not less than the applicable wage rate on the wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. Where a Contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman’s hourly rate) specified in the Contractor’s or subcontractor’s registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice’s level of progress, expressed as a percentage of the journeymen hourly rate specified in the applicable wage determination. Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination. In the event the Office of Apprenticeship Training, Employer and Labor Services, or a State Apprenticeship Agency recognized by the Office, withdraws approval of an apprenticeship program, the Contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
(ii) Trainees. Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration. The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by the Employment and Training Administration. Every trainee must be paid at not less than the rate specified in the approved program for the trainee’s level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed on the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate on the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the Employment and Training Administration shall be paid not less than the applicable wage
DE-EE0002532 Page 20 of 23
rate on the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed. In the event the Employment and Training Administration withdraws approval of a training program, the Contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
(iii) Equal employment opportunity. The utilization of apprentices, trainees and journeymen under this part shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended and 29 CFR part 30.
(5) Compliance with Xxxxxxxx Act requirements. The Contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this Contract.
(6) Contracts and Subcontracts. The Recipient, Subrecipient, the Recipient’s and Subrecipient’s contractors and subcontractor shall insert in any Contracts the clauses contained herein in (a)(1) through (10) and such other clauses as the Department of Energy may by appropriate instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The Recipient shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all of the paragraphs in this clause.
(7) Contract termination: debarment. A breach of the Contract clauses in 29 CFR 5.5 may be grounds for termination of the Contract, and for debarment as a contractor and a subcontractor as provided in 29 CFR 5.12.
(8) Compliance with Xxxxx-Xxxxx and Related Act requirements. All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this Contract.
(9) Disputes concerning labor standards. Disputes arising out of the labor standards provisions of this Contract shall not be subject to the general disputes clause of this Contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the Recipient, Subrecipient, the Contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives.
(10) Certification of eligibility.
(i) By entering into this Contract, the Contractor certifies that neither it (nor he or she) nor any person or firm who has an interest in the Contractor’s firm is a person or firm ineligible to be awarded Government contracts by virtue of section 3(a) of the Xxxxx-Xxxxx Act or 29 CFR 5.12(a)(1).
(ii) No part of this Contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of section 3(a) of the Xxxxx-Xxxxx Act or 29 CFR 5.12(a)(1).
(iii) The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001.
(b) Contract Work Hours and Safety Standards Act. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
(1) Overtime requirements. No Contractor or subcontractor contracting for any part of the Contract work which may require or involve the employment of laborers or mechanics shall require or
DE-EE0002532 Page 21 of 23
permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.
(2) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (b)(1) of this section the Contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such Contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1) of this section.
(3) Withholding for unpaid wages and liquidated damages. The Department of Energy or the Recipient or Subrecipient shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the Contractor or subcontractor under any such contract or any other Federal contract with the same prime Contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (b)(2) of this section.
(4) Contracts and Subcontracts. The Recipient, Subrecipient, and Recipient’s and Subrecipient’s contractor or subcontractor shall insert in any Contracts, the clauses set forth in paragraph (b)(1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The Recipient shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through (4) of this section.
(5) The Contractor or subcontractor shall maintain payrolls and basic payroll records during the course of the work and shall preserve them for a period of three years from the completion of the Contract for all laborers and mechanics, including guards and watchmen, working on the Contract. Such records shall contain the name and address of each such employee, social-security number, correct classifications, hourly rates of wages paid, daily and weekly number of hours worked, deductions made, and actual wages paid. The records to be maintained under this paragraph shall be made available by the Contractor or subcontractor for inspection, copying, or transcription by authorized representatives of the Department of Energy and the Department of Labor, and the Contractor or subcontractor will permit such representatives to interview employees during working hours on the job.
RECIPIENT FUNCTIONS
(1) This delegation of Department of Energy (DOE) functions to the Recipient applies only to DBA effort performed by Subrecipients and Contractors under this award. Those functions are not delegated to the Recipient for any DBA effort performed by employees of the Recipient under this award. On behalf of the Department of Energy (DOE), Recipient shall perform the following functions:
(a) Obtain, maintain, and monitor all DBA certified payroll records submitted by the Subrecipients and Contractors at any tier under this Award;
DE-EE0002532 Page 22 of 23
(b) Review all DBA certified payroll records for compliance with DBA requirements, including applicable DOL wage determinations;
(c) Notify DOE of any non-compliance with DBA requirements by Subrecipients or Contractors at any tier, including any non-compliances identified as the result of reviews performed pursuant to paragraph (b) above;
(d) Address any Subrecipient and any Contractor DBA non-compliance issues; if DBA non-compliance issues cannot be resolved in a timely manner, forward complaints, summary of investigations and all relevant information to DOE;
(e) Provide DOE with detailed information regarding the resolution of any DBA non-compliance issues;
(f) Perform services in support of DOE investigations of complaints filed regarding noncompliance by Subrecipients and Contractors with DBA requirements;
(g) Perform audit services as necessary to ensure compliance by Subrecipients and Contractors with DBA requirements and as requested by the Contracting Officer; and
(h) Provide copies of all records upon request by DOE or DOL in a timely manner.
(2) All records maintained on behalf of the DOE in accordance with paragraph (1) above are federal government (DOE) owned records. DOE or an authorized representative shall be granted access to the records at all times.
(3) In the event of, and in response to any Freedom of Information Act, 5 U.S.C. 552, requests submitted to DOE, Recipient shall provide such records to DOE within 5 business days of receipt of a request from DOE.
DE-EE0002532 Page 23 of 23
ATTACHMENT 1
GDLB-1003
Intellectual Property Provisions (GDLB-1003)
Grant – Special Data Statute
Research, Development, or Demonstration
Large Businesses, State and Local Governments, and Foreign Entities
01. 10 CFR 600.325 Rights in Data - Programs Covered Under Special
Appendix A Data Statutes (OCT 2003)
02. Patent Rights – Waiver (JUL 1996), as modified by
10 C.F.R. 784, DOE Patent Waiver Regulations
03. FAR 52.227-23 Rights to Proposal Data (Technical) (JUN 1987)
04.
NOTE: In reading these provisions, any reference to “contractor” shall mean “recipient,” and any reference to “contract” or “subcontract” shall mean “award” or “subaward.”
DE-EE0002532
01. 10 CFR 600.325 Appendix A, Rights in Data – Programs Covered Under Special Data Statutes (OCT 2003)
Computer Data Bases, as used in this clause, means a collection of data in a form capable of, and for the purpose of, being stored in, processed, and operated on by a computer. The term does not include computer software.
Computer software, as used in this clause, means (i) computer programs which are data comprising a series of instructions, rules, routines, or statements, regardless of the media in which recorded, that allow or cause a computer to perform a specific operation or series of operations and (ii) data comprising source code listings, design details, algorithms, processes, flow charts, formulae and related material that would enable the computer program to be produced, created or compiled. The term does not include computer data bases.
Data, as used in this clause, means recorded information, regardless of form or the media on which it may be recorded. The term includes technical data and computer software. The term does not include information incidental to administration, such as financial, administrative, cost or pricing or management information.
Form, fit, and function data, as used in this clause, means data relating to items, components, or processes that are sufficient to enable physical and functional interchangeability as well as data identifying source, size, configuration, mating and attachment characteristics, functional characteristics, and performance requirements except that for computer software it means data identifying source, functional characteristics, and performance requirements but specifically excludes the source code, algorithm, process, formulae, and flow charts of the software.
Limited rights data, as used in this clause, means data (other than computer software) developed at private expense that embody trade secrets or are commercial or financial and confidential or privileged.
Restricted computer software, as used in this clause, means computer software developed at private expense and that is a trade secret; is commercial or financial and confidential or privileged; or is published copyrighted computer software; including modifications of such computer software.
Protected data, as used in this clause, means technical data or commercial or financial data first produced in the performance of the award which, if it had been obtained from and first produced by a non-federal party, would be a trade secret or commercial or financial information that is privileged or confidential under the meaning of 5 U.S.C. 552(b)(4) and which data is marked as being protected data by a party to the award.
Protected rights, as used in this clause, mean the rights in protected data set forth in the Protected Rights Notice of paragraph (g) of this clause.
Technical data, as used in this clause, means that data which are of a scientific or technical nature. Technical data does not include computer software, but does include manuals and instructional materials and technical data formatted as a computer data base.
Unlimited rights, as used in this clause, means the right of the Government to use, disclose, reproduce, prepare derivative works, distribute copies to the public, and perform publicly and display publicly, in any manner and for any purpose whatsoever, and to have or permit others to do so.
(1) Except as provided in paragraph (c) of this clause regarding copyright, the Government shall have unlimited rights in--
(i) Data specifically identified in this agreement as data to be delivered without restriction;
(ii) Form, fit, and function data delivered under this agreement;
(iii) Data delivered under this agreement (except for restricted computer software) that constitute manuals or instructional and training material for installation, operation, or routine maintenance and repair of items, components, or processes delivered or furnished for use under this agreement; and (iv) All other data delivered under this agreement unless provided otherwise for protected data in accordance with paragraph (g) of this clause or for limited rights data or restricted computer software in accordance with paragraph (h) of this clause.
(2) The Recipient shall have the right to--
(i) Protect rights in protected data delivered under this agreement in the manner and to the extent provided in paragraph (g) of this clause;
(ii) Withhold from delivery those data which are limited rights data or restricted computer software to the extent provided in paragraph (h) of this clause;
(iii) Substantiate use of, add, or correct protected rights or copyrights notices and to take other appropriate action, in accordance with paragraph (e) of this clause; and
(iv) Establish claim to copyright subsisting in data first produced in the performance of this agreement to the extent provided in subparagraph (c)(1) of this clause.
DE-EE0002532 1
(1) Data first produced in the performance of this agreement. Except as otherwise specifically provided in this agreement, the Recipient may establish, without the prior approval of the Contracting Officer, claim to copyright subsisting in any data first produced in the performance of this agreement. If claim to copyright is made, the Recipient shall affix the applicable copyright notice of 17 U.S.C. 401 or 402 and acknowledgment of Government sponsorship (including agreement number) to the data when such data are delivered to the Government, as well as when the data are published or deposited for registration as a published work in the U.S. Copyright Office. For such copyrighted data, including computer software, the Recipient grants to the Government, and others acting on its behalf, a paid-up nonexclusive, irrevocable, worldwide license to reproduce, prepare derivative works, distribute copies to the public, and perform publicly and display publicly, by or on behalf of the Government, for all such data.
(2) Data not first produced in the performance of this agreement. The Recipient shall not, without prior written permission of the Contracting Officer, incorporate in data delivered under this agreement any data that are not first produced in the performance of this agreement and that contain the copyright notice of 17 U.S.C. 401 or 402, unless the Recipient identifies such data and grants to the Government, or acquires on its behalf, a license of the same scope as set forth in subparagraph (c)(1) of this clause; provided, however, that if such data are computer software, the Government shall acquire a copyright license as set forth in subparagraph (h)(3) of this clause if included in this agreement or as otherwise may be provided in a collateral agreement incorporated or made a part of this agreement.
(3) Removal of copyright notices. The Government agrees not to remove any copyright notices placed on data pursuant to this paragraph (c), and to include such notices on all reproductions of the data.
|
(d)
|
Release, Publication and Use of Data
|
(1) The Recipient shall have the right to use, release to others, reproduce, distribute, or publish any data first produced or specifically used by the Recipient in the performance of this contract, except to the extent such data may be subject to the Federal export control or national security laws or regulations, or unless otherwise provided in this paragraph of this clause or expressly set forth in this contract.
(2) The Recipient agrees that to the extent it receives or is given access to data necessary for the performance of this agreement which contain restrictive markings, the Recipient shall treat the data in accordance with such markings unless otherwise specifically authorized in writing by the Contracting Officer.
|
(e)
|
Unauthorized Marking of Data
|
(1) Notwithstanding any other provisions of this agreement concerning inspection or acceptance, if any data delivered under this agreement are marked with the notices specified in subparagraph (g)(2) or (g)(3) of this clause and use of such is not authorized by this clause, or if such data bears any other restrictive or limiting markings not authorized by this agreement, the Contracting Officer may at any time either return the data to the Recipient or cancel or ignore the markings. However, the following procedures shall apply prior to canceling or ignoring the markings.
(i) The Contracting Officer shall make written inquiry to the Recipient affording the Recipient 30 days from receipt of the inquiry to provide written justification to substantiate the propriety of the markings;
(ii) If the Recipient fails to respond or fails to provide written justification to substantiate the propriety of the markings within the 30-day period (or a longer time not exceeding 90 days approved in writing by the Contracting Officer for good cause shown), the Government shall have the right to cancel or ignore the markings at any time after said period and the data will no longer be made subject to any disclosure prohibitions.
(iii) If the Recipient provides written justification to substantiate the propriety of the markings within the period set in subdivision (e)(1)(i) of this clause, the Contracting Officer shall consider such written justification and determine whether or not the markings are to be cancelled or ignored. If the Contracting Officer determines that the markings are authorized, the Recipient shall be so notified in writing. If the Contracting Officer determines, with concurrence of the head of the contracting activity, that the markings are not authorized, the Contracting Officer shall furnish the Recipient a written determination, which determination shall become the final agency decision regarding the appropriateness of the markings unless the Recipient files suit in a court of competent jurisdiction within 90 days of receipt of the Contracting Officer’s decision. The Government shall continue to abide by the markings under this subdivision (e)(1)(iii) until final resolution of the matter either by the Contracting Officer’s determination become final (in which instance the Government shall thereafter have the right to cancel or ignore the markings at any time and the data will no longer be made subject to any disclosure prohibitions), or by final disposition of the matter by court decision if suit is filed.
DE-EE0002532 2
(2) The time limits in the procedures set forth in subparagraph (e)(1) of this clause may be modified in accordance with agency regulations implementing the Freedom of information Act (5 U.S.C. 552) if necessary to respond to a request thereunder.
|
(f)
|
Omitted or Incorrect Markings
|
(1) Data delivered to the Government without either the limited rights or restricted rights notice as authorized by paragraph (g) of this clause, or the copyright notice required by paragraph (c) of this clause, shall be deemed to have been furnished with unlimited rights, and the Government assumes no liability for the disclosure, use, or reproduction of such data. However, to the extent the data has not been disclosed without restriction outside the Government, the Recipient may request, within 6 months (or a longer time approved by the Contracting Officer for good cause shown) after delivery of such data, permission to have notices placed on qualifying data at the Recipient’s expense, and the Contracting Officer may agree to do so if the Recipient--
(i) Identifies the data to which the omitted notice is to be applied;
(ii) Demonstrates that the omission of the notice was inadvertent;
(iii) Establishes that the use of the proposed notice is authorized; and
(iv) Acknowledges that the Government has no liability with respect to the disclosure, use, or reproduction of any such data made prior to the addition of the notice or resulting from the omission of the notice.
(2) The Contracting Officer may also:
(i) Permit correction at the Recipient’s expense of incorrect notices if the Recipient identifies the data on which correction of the notice is to be made, and demonstrates that the correct notice is authorized; or
(ii) Correct any incorrect notices.
|
(g)
|
Rights to Protected Data
|
(1) The Recipient may, with the concurrence of DOE, claim and xxxx as protected data, any data first produced in the performance of this award that would have been treated as a trade secret if developed at private expense. Any such claimed “protected data” will be clearly marked with the following Protected Rights Notice, and will be treated in accordance with such notice, subject to the provisions of paragraphs (e) and (f) of this clause.
PROTECTED RIGHTS NOTICE
These protected data were produced under agreement no. DE-EE0002532 with the U.S. Department of Energy and may not be published, disseminated, or disclosed to others outside the Government until five (5) years from date that the data is generated, unless express written authorization is obtained from the recipient. Upon expiration of the period of protection set forth in this Notice, the Government shall have unlimited rights in this data. This Notice shall be marked on any reproduction of this data, in whole or in part.
(End of notice).
(2) Any such marked Protected Data may be disclosed under obligations of confidentiality for the following purposes:
(a) For evaluation purposes under the restriction that the “Protected Data” be retained in confidence and not be further disclosed; or
(b) To subcontractors or other team members performing work under the Vehicle Technology’s Program
(3) The obligations of confidentiality and restrictions on publication and dissemination shall end for any Protected Data.
(a) At the end of the protected period;
(b) If the data becomes publicly known or available from other sources without a breach of the obligation of confidentiality with respect to the Protected Data;
(c) if the same data is independently developed by someone who did not have access to the Protected Data and such data is made available without obligations of confidentiality; or
(d) If the Recipient disseminates or authorizes another to disseminate such data without obligations of confidentiality.
(4) However, the Recipient agrees that the following types of data are not considered to be protected and shall be provided to the Government when required by this award without any claim that the data are Protected Data. The parties agree that notwithstanding the following lists of types of data, nothing precludes the Government from seeking delivery of
DE-EE0002532 3
additional data in accordance with this award, or from making publicly available additional nonprotected data, nor does the following list constitute any admission by the Government that technical data not on the list is Protected Data.
List of nonprotected data: “Information as defined in the Reporting Requirements Checklist, specifically, within the Final Progress Report.”
(5) The Government’s sole obligation with respect to any protected data shall be as set forth in this paragraph (g).
|
(h)
|
Protection of Limited Rights Data
|
When data other than that listed in subparagraphs (b)(1)(i), (ii), and (iii) of this clause are specified to be delivered under this agreement and such data qualify as either limited rights data or restricted computer software, the Recipient, if the Recipient desires to continue protection of such data, shall withhold such data and not furnish them to the Government under this agreement. As a condition to this withholding the Recipient shall identify the data being withheld and furnish form, fit, and function data in lieu thereof.
The Recipient has the responsibility to obtain from its subrecipients/contractors all data and rights therein necessary to fulfill the Recipient’s obligations to the Government under this agreement. If a subrecipient/contractor refuses to accept terms affording the Government such rights, the Recipient shall promptly bring such refusal to the attention of the Contracting Officer and not proceed with subaward/contract award without further authorization.
|
(j)
|
Additional Data Requirements
|
|
|
(i)
|
In addition to the data specified elsewhere in this agreement to be delivered, the Contracting Officer may, at anytime during agreement performance or within a period of 3 years after acceptance of all items to be delivered under this agreement, order any data first produced or specifically used in the performance of this agreement. This clause is applicable to all data ordered under this subparagraph. Nothing contained in this subparagraph shall require the Recipient to deliver any data the withholding of which is authorized by this clause or data which are specifically identified in this agreement as not subject to this clause. When data are to be delivered under this subparagraph, the Recipient will be compensated for converting the data into the prescribed form, for reproduction, and for delivery.
|
The following data will not be subject to being ordered under the Rights in Data – Programs Covered under Special Data Statutes (OCT 2003), paragraph (j) Additional Data Requirements:
- Detailed data related to proprietary or competition sensitive manufacturing line designs, manufacturing equipment design or fabrication techniques, manufacturing processes, and end item design or fabrication techniques.
|
|
(ii)
|
DOE shall be permitted to call for the delivery of the data listed in (i) above only in the following circumstances:
|
(1) To defend litigation brought against the government, including patent infringement, environmental and tort claims;
(2) To pursue litigation brought by the government against Grantee or one of Grantee’s team members or subcontractors growing out of work performed under this Grant;
(3) In the event the Government requires the information for investigations of fraud, mischarging, or similar charges against Recipient or one of its team members or subcontractors;
(4) In the event of a catastrophic occurrence at the facility such as an explosion, accident or hazardous material release, where the Government requires the information to conduct an analysis of the occurrence; or
DE-EE0002532 4
|
|
(iii)
|
DOE shall have the right to inspect the data listed in (i) above at any time.
|
|
(k)
|
The Recipient agrees, except as may be otherwise specified in this agreement for specific data items listed as not subject to this paragraph, that the Contracting Officer or an authorized representative may, up to three years after acceptance of all items to be delivered under this contract, inspect at the Recipient’s facility any data withheld pursuant to paragraph (h) of this clause, for purposes of verifying the Recipient’s assertion pertaining to the limited rights or restricted rights status of the data or for evaluating work performance. Where the Recipient whose data are to be inspected demonstrates to the Contracting Officer that there would be a possible conflict of interest if the inspection were made by a particular representative, the Contracting Officer shall designate an alternate inspector.
|
(End of clause)
02. Patent Rights - Waiver (JUL 1996), as modified by 10 C.F.R. 784, DOE Patent Waiver Regulations
(a) Definitions.
As used in this clause:
Background patent means a domestic patent covering an invention or discovery which is not a Subject Invention and which is owned or controlled by the Contractor at any time through the completion of this contract:
|
|
(i)
|
Which the Contractor, but not the Government, has the right to license to others without obligation to pay royalties thereon, and
|
|
|
(ii)
|
Infringement of which cannot reasonably be avoided upon the practice of any specific process, method, machine, manufacture or composition of matter (including relatively minor modifications thereof) which is a subject of the research, development, or demonstration work performed under this contract.
|
Contract means any contract, grant, agreement, understanding, or other arrangement, which includes research, development, or demonstration work, and includes any assignment or substitution of parties.
DOE patent waiver regulations means the Department of Energy patent waiver regulations at 10 CFR Part 784.
Invention as used in this clause, means any invention or discovery which is or may be patentable or otherwise protectable under Title 35 of the United States Code or any novel variety of plant that is or may be protectable under the Plant Variety Protection Act (7 U.S.C. 2321 et seq.).
Made when used in relation to any invention means the conception or first actual reduction to practice of such invention.
Nonprofit organization means a university or other institution of higher education or an organization of the type described in section 501(c)(3) of the Internal Revenue Code of 1954 (26 U.S.C. 501(c)) and exempt from taxation under section 501(a) of the Internal Revenue Code (26 U.S.C. 501(a)) or any nonprofit scientific or educational organization qualified under a state nonprofit organization statute.
Patent Counsel means the Department of Energy Patent Counsel assisting the procuring activity.
Practical application means to manufacture, in the case of a composition or product; to practice, in the case of a process or method; or to operate, in the case of a machine or system; and, in each case, under such conditions as to establish that the invention is being utilized and that its benefits are, to the extent permitted by law or Government regulations, available to the public on reasonable terms.
Secretary means the Secretary of Energy.
Small business firm means a small business concern as defined at Section 2 of the Pub. L. 85-536 (15 U.S.C. 632) and implementing regulations of the Administrator of the Small Business Administration. For the purpose of this clause, the size standards for small business concerns involved in Government procurement and subcontracting at 13 CFR 121.3-8 and 13 CFR 121.3-12, respectively, will be used.
5E-EE0002532 5
Subject invention means any invention of the Contractor conceived or first actually reduced to practice in the course of or under this contract, provided that in the case of a variety of plant, the date of determination (as defined in section 41(d) of the Plant Variety Protection Act (7 U.S.C. 2401(d)) must also occur during the period of contract performance.
(b) Allocation of principal rights.
Whereas DOE has granted a waiver of rights to subject inventions to the Contractor, the Contractor may elect to retain the entire right, title, and interest throughout the world to each subject invention subject to the provisions of this clause and 35 U.S.C. “202 and 203. With respect to any subject invention in which the Contractor elects to retain title, the Federal Government shall have a nonexclusive, nontransferable, irrevocable, paid-up license to practice or have practiced for or on behalf of the United States the subject invention throughout the world.
(c) Invention disclosure, election of title, and filing of patent applications by Contractor.
(1) The Contractor shall disclose each subject invention to the Patent Counsel within six months after conception or first actual reduction to practice, whichever occurs first in the course of or under this contract, but in any event, prior to any sale, public use, or public disclosure of such invention known to the Contractor. The disclosure to the Patent Counsel shall be in the form of a written report and shall identify the inventors and the contract under which the invention was made. It shall be sufficiently complete in technical detail to convey a clear understanding, to the extent known at the time of the disclosure, of the nature, purpose, operation, and physical, chemical, biological, or electrical characteristics of the invention. The disclosure shall also identify any publication, on sale, or public use of the invention and whether a manuscript describing the invention has been submitted for publication and, if so, whether it has been accepted for publication at the time of disclosure. In addition, after disclosure to the Patent Counsel, the Contractor shall promptly notify the Patent Counsel of the acceptance of any manuscript describing the invention for publication or of any on sale or public use planned by the Contractor.
(2) The Contractor shall elect in writing whether or not to retain title to any such invention by notifying the Patent Counsel at the time of disclosure or within 8 months of disclosure, as to those countries (including the United States) in which the Contractor will retain title; provided, that in any case where publication, on sale, or public use has initiated the 1-year statutory period wherein valid patent protection can still be obtained in the United States, the period of election of title may be shortened by the Agency to a date that is no more than 60 days prior to the end of the statutory period. The Contractor shall notify the Patent Counsel as to those countries (including the United States) in which the Contractor will retain title not later than 60 days prior to the end of the statutory period.
(3) The Contractor shall file its United States patent application on an elected invention within 1 year after election, but not later than at least 60 days prior to the end of any statutory period wherein valid patent protection can be obtained in the United States after a publication, on sale, or public use. The Contractor shall file patent applications in additional countries (including the European Patent Office and under the Patent Cooperation Treaty) within either 10 months of the corresponding initial patent application or 6 months from the date permission is granted by the Commissioner of Patents and Trademarks to file foreign patent applications where foreign filing has been prohibited by a Secrecy Order.
(4) Requests for extension of the time for disclosure to the Patent Counsel, election, and filing may, at the discretion of DOE, be granted, and will normally be granted unless the Patent Counsel has reason to believe that a particular extension would prejudice the Government’s interest.
(d) Conditions when the Government may obtain title notwithstanding an existing waiver.
The Contractor shall convey to DOE, upon written request, title to any subject invention--
(1) If the Contractor elects not to retain title to a subject invention;
(2) If the Contractor fails to disclose or elect the subject invention within the times specified in paragraph (c) of this clause (provided that DOE may only request title within 60 days after learning of the Contractor’s failure to report or elect within the specified times);
(3) In those countries in which the Contractor fails to file patent applications within the times specified in paragraph (c) of this clause; provided, however, that if the Contractor has filed a patent application in a country after the times
DE-EE0002532 6
specified in paragraph (c) of this clause, but prior to its receipt of the written request of DOE, the Contractor shall continue to retain title in that country;
(4) In any country in which the Contractor decides not to continue the prosecution of any application for, to pay the maintenance fees on, or defend in reexamination or opposition proceeding on, a patent on a subject invention; or
(5) If the waiver authorizing the use of this clause is terminated as provided in paragraph (p) of this clause.
(e) Minimum rights to Contractor when the Government retains title.
(1) The Contractor shall retain a nonexclusive, royalty-free license throughout the world in each subject invention to which the Government obtains title under paragraph (d) of this clause except if the Contractor fails to disclose the subject invention within the times specified in paragraph (c) of this clause. The Contractor’s license extends to its domestic subsidiaries and affiliates, if any, within the corporate structure of which the Contractor is a part and includes the right to grant sublicenses of the same scope to the extent the Contractor was legally obligated to do so at the time the contract was awarded. The license is transferable only with the approval of DOE except when transferred to the successor of that part of the Contractor’s business to which the invention pertains.
(2) The Contractor’s domestic license may be revoked or modified by DOE to the extent necessary to achieve expeditious practical application of the subject invention pursuant to an application for an exclusive license submitted in accordance with applicable provisions in 37 CFR part 404 and DOE licensing regulations. This license shall not be revoked in that field of use or the geographical areas in which the Contractor has achieved practical application and continues to make the benefits of the invention reasonably accessible to the public. The license in any foreign country may be revoked or modified at the discretion of DOE to the extent the Contractor, its licensees, or its domestic subsidiaries or affiliates have failed to achieve practical application in that foreign country.
(3) Before revocation or modification of the license, DOE shall furnish the Contractor a written notice of its intention to revoke or modify the license, and the Contractor shall be allowed 30 days (or such other time as may be authorized by DOE for good cause shown by the Contractor) after the notice to show cause why the license should not be revoked or modified. The Contractor has the right to appeal, in accordance with applicable agency licensing regulations and 37 CFR part 404 concerning the licensing of Government-owned inventions, any decision concerning the revocation or modification of its license.
(f) Contractor action to protect the Government’s interest.
(1) The Contractor agrees to execute or to have executed and promptly deliver to DOE all instruments necessary to:
(i) establish or confirm the rights the Government has throughout the world in those subject inventions to which the Contractor elects to retain title, and
(ii) convey title to DOE when requested under paragraphs (d) and (n)(2) of this clause, and to enable the Government to obtain patent protection throughout the world in that subject invention.
(2) The Contractor agrees to require, by written agreement, its employees, other than clerical and nontechnical employees, to disclose promptly in writing to personnel identified as responsible for the administration of patent matters and in a format suggested by the Contractor each subject invention made under contract in order that the Contractor can comply with the disclosure provisions of paragraph (c) of this clause, and to execute all papers necessary to file patent applications on subject inventions and to establish the Government’s rights in the subject inventions. This disclosure format should require, as a minimum, the information required by paragraph (c)(1) of this clause. The Contractor shall instruct such employees through employee agreements or other suitable educational programs on the importance of reporting inventions in sufficient time to permit the filing of patent applications prior to U.S. or foreign statutory bars.
(3) The Contractor shall notify DOE of any decision not to continue the prosecution of a patent application, pay maintenance fees, or defend in a reexamination or opposition proceeding on a patent, in any country, not less than 30 days before the expiration of the response period required by the relevant patent office.
DE-EE0002532 7
(4) The Contractor agrees to include, within the specification of any United States patent application and any patent issuing thereon covering a subject invention, the following statement: “This invention was made with Government support under (identify the contract) awarded by DOE. The Government has certain rights in this invention.”
(5) The Contractor shall establish and maintain active and effective procedures to assure that subject inventions are promptly identified and disclosed to Contractor personnel responsible for patent matters within 6 months of conception and/or first actual reduction to practice, whichever occurs first in the course of or under this contract. These procedures shall include the maintenance of laboratory notebooks or equivalent records and other records as are reasonably necessary to document the conception and/or the first actual reduction to practice of subject inventions, and records that show that the procedures for identifying and disclosing the inventions are followed. Upon request, the Contractor shall furnish the Patent Counsel a description of such procedures for evaluation and for determination as to their effectiveness.
(6) The Contractor agrees, when licensing a subject invention, to arrange to avoid royalty charges on acquisitions involving Government funds, including funds derived through Military Assistance Program of the Government or otherwise derived through the Government; to refund any amounts received as royalty charges on the subject invention in acquisitions for, or on behalf of, the Government; and to provide for such refund in any instrument transferring rights in the invention to any party.
(7) The Contractor shall furnish the Patent Counsel the following:
(i.) Interim reports every 12 months (or such longer period as may be specified by the Patent Counsel) from the date of the contract, listing subject inventions during that period and stating that all subject inventions have been disclosed or that there are no such inventions.
(ii.) A final report, within 3 months after completion of the contracted work, listing all subject inventions or stating that there were no such inventions, and listing all subcontracts at any tier containing a patent rights clause or certifying that there were no such subcontracts.
(8) The Contractor shall promptly notify the Patent Counsel in writing upon the award of any subcontract at any tier containing a patent rights clause by identifying the subcontractor, the applicable patent rights clause, the work to be performed under the subcontract, and the dates of award and estimated completion. Upon request of the Patent Counsel, the Contractor shall furnish a copy of such subcontract, and no more frequently than annually, a listing of the subcontracts that have been awarded.
(9) The Contractor shall provide, upon request, the filing date, serial number and title, a copy of the patent application (including an English-language version if filed in a language other than English), and patent number and issue date for any subject invention for which the Contractor has retained title.
(10) Upon request, the Contractor shall furnish the Government an irrevocable power to inspect and make copies of the patent application file.
(g) Subcontracts.
(1) Unless otherwise directed by the Contracting Officer, the Contractor shall include the clause at 48 CFR 952.227-11, suitably modified to identify the parties, in all subcontracts, regardless of tier, for experimental, developmental, or research work to be performed by a small business firm or nonprofit organization, except where the work of the subcontract is subject to an Exceptional Circumstances Determination by DOE. In all other subcontracts, regardless of tier, for experimental, developmental, demonstration, or research work, the Contractor shall include the patent rights clause at 48 CFR 952.227-13 (suitably modified to identify the parties).
(2) The Contractor shall not, as part of the consideration for awarding the subcontract, obtain rights in the subcontractor’s subject inventions.
(3) In the case of subcontractors at any tier, the Department, the subcontractor, and Contractor agree that the mutual obligations of the parties created by this clause constitute a contract between the subcontractor and the Department with respect to those matters covered by this clause.
DE-EE0002532 8
(4) The Contractor shall promptly notify the Contracting Officer in writing upon the award of any subcontract at any tier containing a patent rights clause by identifying the subcontractor, the applicable patent rights clause, the work to be performed under the subcontract, and the dates of award and estimated completion. Upon request of the Contracting Officer, the Contracting Officer shall furnish a copy of such subcontract, and, no more frequently than annually, a listing of the subcontracts that have been awarded.
(h) Reporting on utilization of subject inventions.
The Contractor agrees to submit on request periodic reports no more frequently than annually on the utilization of a subject invention or on efforts at obtaining such utilization that are being made by the Contractor and any of its licensees or assignees. Such reports shall include information regarding the status of development, date of first commercial sale or use, gross royalties received by the Contractor, and such other data and information as DOE may reasonably specify. The Contractor also agrees to provide additional reports as may be requested by DOE in connection with any march-in proceedings undertaken by DOE in accordance with paragraph (j) of this clause. To the extent data or information supplied under this paragraph is considered by the Contractor, its licensee or assignee to be privileged and confidential and is so marked, DOE agrees that, to the extent permitted by law, it shall not disclose such information to persons outside the Government.
(i) Preference for United States industry.
Notwithstanding any other provision of this clause, the Contractor agrees that neither it nor any assignee will grant to any person the exclusive right to use or sell any subject invention in the United States unless such person agrees that any products embodying the subject invention will be manufactured substantially in the United States. However, in individual cases, the requirement for such an agreement may be waived by DOE upon a showing by the Contractor or its assignee that reasonable but unsuccessful efforts have been made to grant licenses on similar terms to potential licensees that would be likely to manufacture substantially in the United States or that under the circumstances domestic manufacture is not commercially feasible.
(j) March-in rights.
The Contractor agrees that with respect to any subject invention in which it has acquired title, DOE has the right in accordance with the procedures in 48 CFR 27.304-1(g) to require the Contractor, an assignee, or exclusive licensee of a subject invention to grant a nonexclusive, partially exclusive, or exclusive license in any field of use to a responsible applicant or applicants, upon terms that are reasonable under the circumstances, and if the Contractor, assignee, or exclusive licensee refuses such a request, DOE has the right to grant such a license itself if DOE determines that--
(1) Such action is necessary because the Contractor or assignee has not taken, or is not expected to take within a reasonable time, effective steps to achieve practical application of the subject invention in such field of use;
(2) Such action is necessary to alleviate health or safety needs which are not reasonably satisfied by the Contractor, assignee, or their licensees;
(3) Such action is necessary to meet requirements for public use specified by Federal regulations and such requirements are not reasonably satisfied by the Contractor, assignee, or licensees; or
(4) Such action is necessary because the agreement required by paragraph (i) of this clause has not been obtained or waived or because a licensee of the exclusive right to use or sell any subject invention in the United States is in breach of such agreement.
(k) Background Patents [reserved]
(l) Communications.
All reports and notifications required by this clause shall be submitted to the Patent Counsel unless otherwise instructed.
DE-EE0002532 9
(m) Other inventions.
Nothing contained in this clause shall be deemed to grant to the Government any rights with respect to any invention other than a subject invention, except with respect to Background Patents, above.
(n) Examination of records relating to inventions.
(1) The Contracting Officer or any authorized representative shall, until 3 years after final payment under this contract, have the right to examine any books (including laboratory notebooks), records, and documents of the Contractor relating to the conception or first actual reduction to practice of inventions in the same field of technology as the work under this contract to determine whether--
(i) Any such inventions are subject inventions;
(ii) The Contractor has established and maintains the procedures required by paragraphs (f)(2) and (f)(5) of this clause; and
(iii) The Contractor and its inventor have complied with the procedures.
(2) If the Contracting Officer determines that an inventor has not disclosed a subject invention to the Contractor in accordance with the procedures required by paragraph (f)(5) of this clause, the Contracting Officer may, within 60 days after the determination, request title in accordance with paragraphs (d)(2) and (d)(3) of this clause. However, if the Contractor establishes that the failure to disclose did not result from the Contractor’s fault or negligence, the Contracting Officer shall not request title.
(3) If the Contracting Officer learns of an unreported Contractor invention which the Contracting Officer believes may be a subject invention, the Contractor may be required to disclose the invention to DOE for a determination of ownership rights.
(4) Any examination of records under this paragraph shall be conducted in such a manner as to protect the confidentiality of the information involved.
(o) Withholding of payment.
NOTE: This paragraph does not apply to subcontracts or grants.
(1) Any time before final payment under this contract, the Contracting Officer may, in the Government’s interest, withhold payment until a reserve not exceeding $50,000 or 5 percent of the amount of the contract, whichever is less, shall have been set aside if, in the Contracting Officer’s opinion, the Contractor fails to--
(i) Establish, maintain, and follow effective procedures for identifying and disclosing subject inventions pursuant to paragraph (f)(5) of this clause;
(ii) Disclose any subject invention pursuant to paragraph (c)(1) of this clause;
(iii) Deliver acceptable interim reports pursuant to paragraph (f)(7)(l) of this clause;
(iv) Provide the information regarding subcontracts pursuant to paragraph (f)(6) of this clause; or
(v) Convey to the Government, using a DOE-approved form, the title and/or rights of the Government in each subject invention as required by this clause.
(2) Such reserve or balance shall be withheld until the Contracting Officer has determined that the Contractor has rectified whatever deficiencies exist and has delivered all reports, disclosures, and other information required by this clause.
(3) Final payment under this contract shall not be made before the Contractor delivers to the Patent Counsel all disclosures of subject inventions required by paragraph (c)(1) of this clause, an acceptable final report pursuant to paragraph (f)(7)(ii) of this clause, and all past due confirmatory instruments, and the Patent Counsel has issued a patent clearance certification to the Contracting Officer.
(4) The Contracting Officer may decrease or increase the sums withheld up to the maximum authorized above. If the maximum amount authorized above is already being withheld under other provisions of the contract, no additional amount
DE-EE0002532 10
shall be withheld under this paragraph. The withholding of any amount or the subsequent payment thereof shall not be construed as a waiver of any Government right.
(p) Waiver Terminations.
Any waiver granted to the Contractor authorizing the use of this clause (including any retention of rights pursuant thereto by the Contractor under paragraph (b) of this clause) may be terminated at the discretion of the Secretary or his designee in whole or in part, if the request for waiver by the Contractor is found to contain false material statements or nondisclosure of material facts, and such were specifically relied upon by DOE in reaching the waiver determination. Prior to any such termination, the Contractor will be given written notice stating the extent of such proposed termination and the reasons therefore, and a period of 30 days, or such longer period as the Secretary or his designee shall determine for good cause shown in writing, to show cause why the waiver of rights should not be so terminated. Any waiver termination shall be subject to the Contractor’s minimum license as provided in paragraph (e) of this clause.
(q) Atomic Energy.
No claim for pecuniary award or compensation under the provisions of the Atomic Energy Act of 1954, as amended, shall be asserted by the Contractor or its employees with respect to any invention or discovery made or conceived in the course of or under this contract.
(r) Publication.
It is recognized that during the course of work under this contract, the contractor or its employees may from time to time desire to release or publish information regarding scientific or technical developments conceived or first actually reduced to practice in the course of or under this contract. In order that public disclosure of such information will not adversely affect the patent interests of DOE or the contractor, approval for release of publication shall be secured from Patent Counsel prior to any such release or publication. In appropriate circumstances, and after consultation with the contractor, Patent Counsel may waive the right of prepublication review.
(s) Forfeiture of rights in unreported subject inventions.
(1) The contractor shall forfeit and assign to the Government, at the request of the Secretary of Energy or designee, all rights in any subject invention which the contractor fails to report to Patent Counsel within six months after the time the contractor:
(i) Files or causes to be filed a United States or foreign patent application thereon; or
(ii) Submits the final report required by paragraph (f)(7)(ii) of this clause, whichever is later.
(2) However, the Contractor shall not forfeit rights in a subject invention if, within the time specified in paragraph (n)(1) of this clause, the contractor:
(i) Prepares a written decision based upon a review of the record that the invention was neither conceived nor first actually reduced to practice in the course of or under the contract and delivers the decision to Patent Counsel, with a copy to the Contracting Officer; or
(ii) Contending that the subject invention is not a subject invention, the contractor nevertheless discloses the subject invention and all facts pertinent to this contention to the Patent Counsel, with a copy to the Contracting Officer, or
(iii) Establishes that the failure to disclose did not result from the contractor’s fault or negligence.
(3) Pending written assignment of the patent application and patents on a subject invention determined by the Contracting Officer to be forfeited (such determination to be a Final Decision under the Disputes clause of this contract), the contractor shall be deemed to hold the invention and the patent applications and patents pertaining thereto in trust for the Government. The forfeiture provision of this paragraph shall be in addition to and shall not supersede any other rights and remedies which the Government may have with respect to subject inventions.
(t) U. S. Competitiveness
DE-EE0002532 11
The Contractor agrees that any products embodying any waived invention or produced through the use of any waived invention will be manufactured substantially in the United States unless the Contractor can show to the satisfaction of the DOE that it is not commercially feasible to do so. In the event the DOE agrees to foreign manufacture, there will be a requirement that the Government’s support of the technology be recognized in some appropriate manner, e.g., recoupment of the Government’s investment, etc. The Contractor agrees that it will not license, assign or otherwise transfer any waived invention to any entity unless that entity agrees to these same requirements. Should the Contractor or other such entity receiving rights in the invention undergo a change in ownership amounting to a controlling interest, then the waiver, assignment, license, or other transfer of rights in the waived invention is suspended until approved in writing by the DOE.
(End of clause)
03. FAR 52.227-23 Rights to Proposal Data (Technical) (JUN 1987)
Except for data contained on pages 8, 10, 18, 19, 29, and 30 of the Project Narrative, it is agreed that as a condition of award of this contract, and notwithstanding the conditions of any notice appearing thereon, the Government shall have unlimited rights (as defined in the “Rights in Data--General” clause contained in this contract) in and to the technical data contained in the proposal dated May 15, 2009, upon which this contract is based.
DE-EE0002532 12
ATTACHMENT 2
STATEMENT OF PROJECT OBJECTIVES
FutureFuel Chemical Company
Recovery Act – Establish and Expand Commercial Production of Graphite
Anode Materials for High Performance Lithium-ion Batteries
A. PROJECT OBJECTIVES
FutureFuel Chemical Company (FFCC) will design, construct, and operate a commercial-scale plant to produce Intermediate Anode Powder – the key component in *** line of *** Anode Materials. ***. ***. Anode Materials are based on patented technology and proprietary processing methods developed by ***, and are marketed globally. The performance of anodes produced with *** Anode Material has been shown to be superior to industry benchmark products, and *** Anode Material has been adopted for use in power tools, defense, automotive, and utility load management applications. *** Anode Material is currently being purchased by *** cell and battery manufacturers and is qualified in *** electric vehicle platforms. *** has produced *** Anode Materials in its semi-works facility since ***, which has now reached capacity operation of *** lbs/year. In order to meet growing product demand and maintain domestic manufacture, *** has entered into an exclusive agreement for FFCC to establish full commercial-scale production of Intermediate Anode Powder to meet anticipated market requirements for EDV applications.
B. PROJECT SCOPE
An existing FFCC manufacturing plant in Batesville, Arkansas, will be retrofitted to process the Intermediate Anode Material. Design of the plant will be based on patented technology and proprietary manufacturing processing methods developed by ***. This technology has been demonstrated in ***, research and semi-works facility. The FFCC plant will be at least ten times the scale of *** semi-works facility.
By leveraging existing manufacturing assets, infrastructure, and environmental permits, FFCC will complete the Intermediate Anode Powder plant for a fraction of the capital cost of a new facility, and will be ready to commence commercial production in the second quarter of 2011. The plant will be designed with the capability to produce Intermediate Anode Powder used in all commercial and developmental *** Anode products. The FFCC manufacturing plant to be reconfigured includes 70% of the major process equipment and 60% of the pumps required for the program. Construction of additional manufacturing building floor space will not be required for the completion of the project. Site utility systems have adequate capacity to supply the requirements of the plant
DE-EE0002532 1
with the exception of nitrogen. Only minor modifications to FFCC’s Title V air permit are required to initiate production of the Intermediate Anode Material.
The FFCC plant will have the capacity to process *** pounds per year of Intermediate Anode Powder, sufficient for supplying over *** hybrid-electric vehicles. Installation of the Intermediate Anode Powder plant is expected to require ≈100 construction positions. At full capacity, the plant will result in the creation of 33 new jobs.
C. TASKS TO BE PERFORMED
Task 1 Revise the Project Management Plan and submit to DOE.
The project management team will update the PMP to reflect any details of the award negotiation process with DOE. As the project progresses the team will use the PMP to report progress to DOE per the deliverables described in section D of this SOPO. These reports will include project status, progress toward achieving milestones, and schedule and budget variances.
Task 2 Complete Design Engineering
The engineering required for all systems will be completed, including; *** handling, *** recycle, *** tank and unloading station, ***, loading dock, and the nitrogen/air separation unit.
Task 3 Purchase Equipment and Major Components;
Equipment needs for all systems will be specified, vendor bids solicited, and equipment purchased. Equipment includes; nitrogen/air separation unit, melt extruder, structural steel for *** and ***, and the *** unloading station.
Task 4 Equipment Installation
Equipment will be installed including piping, and controls for *** and the ***.
Task 5 Construct the *** and ***, the Loading Dock, and the Nitrogen/Air Separation Unit
The *** handling and storage system will be constructed. This includes the *** tank, the ***, the *** unloading station, the loading dock, and the nitrogen/air separation unit.
Task 6 Obtain All Required Permits
All of the required permits will be obtained to accommodate the additional processing steps and emissions associated with the production of Intermediate Anode Material.
Task 7 Train Plant Operators
Plant operators for the Intermediate Anode Material production facility will be hired and trained.
DE-EE0002532 2
Task 8 Checkout, Commission, and Start Up Plant
The manufacturing process will be brought up to design production rates and the product will be evaluated to insure that it is within the manufacturing specifications. This task includes verifying the installation of equipment, piping, controls and the function of process control software.
Task 9 Complete Qualification Trial
A trial run of the complete process, from raw material to the final product, will be performed. All of the material handling and processing equipment will be brought up to production rates and the production process will be evaluated.
This task includes the completion of the Additional Technical Deliverables for Area of Interest 2; FFCC will collaborate with *** and *** customers and development partners to provide the deliverables described in Section D.
D. DELIVERABLES
Periodic reports shall be submitted in accordance with the “Federal Assistance Reporting Checklist” and the instructions accompanying the checklist.
In addition to deliverables required in the Federal Reporting Requirements Checklist, other technical deliverables are:
|
|
·
|
500 gram sample representative of the material produced under the award
|
|
|
·
|
10 kg sample of the final, battery-grade material into which the Recipient’s product is incorporated.
|
|
Note:
|
DOE’s intent is to fabricate and test battery cells containing the battery grade material. The sample should be accompanied by a detailed spec sheet and a process description that identifies any special steps necessary to build cells using the material. (e.g. identify particular binder, electrolyte, or additive necessary to get best performance.)
|
E. BRIEFINGS/TECHNICAL PRESENTATIONS
Briefings shall be presented, on an approximately semi-annual basis and consistent with the DOE annual program reviews. The final briefing shall be presented within 30 days of the expiration of the award. These briefings shall be made at either the DOE/NETL locations (Washington DC / Pittsburgh, PA / Morgantown, WV), or at one of the project team sites. In addition, a presentation shall be required at the annual DOE Program Merit Review.
DE-EE0002532 3
DOE F 4600.2
(09/09)
All Other Editions Are Obsolete
ATTACHMENT 3
U.S. Department of Energy
FEDERAL ASSISTANCE REPORTING CHECKLIST
AND INSTRUCTIONS
|
1. Identification Number:
DE-EE0002532
|
2. Programs/Project Title:
Recovery Act – Establish and Expand Commercial Production of Graphite Anode Materials for High Performance Lithium-ion Batteries
|
|
3. Recipient:
FutureFuel Chemical Company
|
|
4. Reporting Requirements:
A. MANAGEMENT REPORTING
T Progress Report
T Special Status Report
|
Frequency
|
No. of Copies
|
Addresses
|
|
Q, F*
A
|
Upload only 1 copy to the address in the next column at the interval specified in the previous column
|
xxxxx://xxx.xxxx-
xxx.xxxxxx.xxx/XxxxxxXxxxxxx.xxxx
|
|
B. SCIENTIFIC/TECHNICAL REPORTING
(Reports/Products must be submitted with appropriate DOE F 241. The 241 forms are available at xxx.xxxx.xxx/xxxxx)
| | | |
|
Report/Product
£ Final Scientific/Technical Report
£ Conference papers/proceedings*
£ Software/Manual
£ Other (see Special Instructions)
* Scientific and technical conferences only
|
Form
DOE F 241.3
DOE F 241.3
DOE F 241.4
DOE F 241.3
| | |
xxxx://xxx.xxxx.xxx/xxxxx-0000
xxxx://xxx.xxxx.xxx/xxxxx-0000
xxxx://xxx.xxxx.xxx/xxxxx/000-0xxx.xxx
|
|
C. FINANCIAL REPORTING
T SF-425, Federal Financial Report
|
Q, F
| |
xxxxx://xxx.xxxx-
xxx.xxxxxx.xxx/XxxxxxXxxxxxx.xxxx
|
|
D. CLOSEOUT REPORTING
T Patent Certification
T Property Certification
£ Other (see Special Instructions)
|
F
F
| |
xxxxx://xxx.xxxx-
xxx.xxxxxx.xxx/XxxxxxXxxxxxx.xxxx
|
|
E. OTHER REPORTING
T Annual Indirect Cost Proposal
T Annual Inventory Report of Federally Owned Property, if any
£ Other
|
A
A
| |
xxxxx://xxx.xxxx-
xxx.xxxxxx.xxx/XxxxxxXxxxxxx.xxxx
|
|
F. AMERICAN RECOVERY AND REINVESTMENT ACT REPORTING
T Reporting and Registration Requirements
|
D
| |
xxxx://xxx.xxxxxxxxxxxxxxxx.xxx
|
|
FREQUENCY CODES AND DUE DATES:
A – Within 5 Calendar days after events or as specified
F – Final; 90 calendar days after expiration or termination of the award.
Y – Yearly; 90 days after the end of the reporting period.
|
S – Semiannually; within 30 days after end of reporting period.
Q – Quarterly; within 30 days after end of the reporting period.
D – Quarterly: within 10 days after end of the reporting period.
|
|
5. Special Instructions: Forms are available at xxxxx://xxx.xxxx-xxx.xxxxxx.xxx/xxxxx.xxxx.
*The Recipient shall submit a Final Progress Report which shall document and summarize all work performed during the award period in a comprehensive manner. This report shall not merely be a compilation of information contained in previously submitted quarterly reports, but shall present that information in an integrated fashion. It must contain an estimate of total production capacity for the facility(ies) funded by this award, including production capacity of any material or component sub-awards. It shall also present the unit test plan based on at least one OEM specification, as well as unit performance and abuse test results.
|
Federal Assistance Reporting Instructions (9/09)
Progress Report
The Progress Report must provide a concise narrative assessment of the status of work and include the following information and any other information identified under Special Instructions on the Federal Assistance Reporting Checklist:
|
|
1.
|
The DOE award number and name of the recipient.
|
|
|
2.
|
The project title and name of the project director/principal investigator.
|
|
|
3.
|
Date of report and period covered by the report.
|
|
|
4.
|
A comparison of the actual accomplishments with the goals and objectives established for the period and reasons why the established goals were not met.
|
|
|
5.
|
A discussion of what was accomplished under these goals during this reporting period, including major activities, significant results, major findings or conclusions, key outcomes or other achievements. This section should not contain any proprietary data or other information not subject to public release. If such information is important to reporting progress, do not include the information, but include a note in the report advising the reader to contact the Principal Investigator or the Project Director for further information.
|
|
|
6.
|
Cost Status. Show approved budget by budget period and actual costs incurred. If cost sharing is required break out by DOE share, recipient share, and total costs.
|
|
|
7.
|
Schedule Status. List milestones, anticipated completion dates and actual completion dates. If you submitted a project management plan with your application, you must use this plan to report schedule and budget variance. You may use your own project management system to provide this information.
|
|
|
8.
|
Any changes in approach or aims and reasons for change. Remember significant changes to the objectives and scope require prior approval by the contracting officer.
|
|
|
9.
|
Actual or anticipated problems or delays and actions taken or planned to resolve them.
|
|
|
10.
|
Any absence or changes of key personnel or changes in consortium/teaming arrangement.
|
|
|
11.
|
A description of any product produced or technology transfer activities accomplished during this reporting period, such as:
|
2
|
|
A.
|
Publications (list journal name, volume, issue); conference papers; or other public releases of results. Attach or send copies of public releases to the DOE Program Manager identified in Block 15 of the Assistance Agreement Cover Page.
|
|
|
B.
|
Web site or other Internet sites that reflect the results of this project.
|
|
|
C.
|
Networks or collaborations fostered.
|
|
|
D.
|
Technologies/Techniques.
|
|
|
E.
|
Inventions/Patent Applications
|
|
|
F.
|
Other products, such as data or databases, physical collections, audio or video, software or netware, models, educational aid or curricula, instruments or equipment.
|
Special Status Report
The recipient must report the following events by e-mail as soon as possible after they occur:
|
|
1.
|
Developments that have a significant favorable impact on the project.
|
|
|
2.
|
Problems, delays, or adverse conditions which materially impair the recipient’s ability to meet the objectives of the award or which may require DOE to respond to questions relating to such events from the public The recipient must report any of the following incidents and include the anticipated impact and remedial action to be taken to correct or resolve the problem/condition:
|
|
|
a.
|
Any single fatality or injuries requiring hospitalization of five or more individuals.
|
|
|
b.
|
Any significant environmental permit violation.
|
|
|
c.
|
Any verbal or written Notice of Violation of any Environmental, Safety, and Health statutes.
|
|
|
d.
|
Any incident which causes a significant process or hazard control system failure.
|
|
|
e.
|
Any event which is anticipated to cause a significant schedule slippage or cost increase.
|
|
|
f.
|
Any damage to Government-owned equipment in excess of $50,000.
|
|
|
g.
|
Any other incident that has the potential for high visibility in the media.
|
3
|
B.
|
SCIENTIFIC/TECHNICAL REPORTS
|
Final Scientific/Technical Report
Content. The final scientific/technical report must include the following information and any other information identified under Special Instructions on the Federal Assistance Reporting Checklist:
|
|
1.
|
Identify the DOE award number; name of recipient; project title; name of project director/principal investigator; and consortium/teaming members.
|
|
|
2.
|
Display prominently on the cover of the report any authorized distribution limitation notices, such as patentable material or protected data. Reports delivered without such notices may be deemed to have been furnished with unlimited rights, and the Government assumes no liability for the disclosure, use or reproduction of such reports.
|
|
|
3.
|
Provide an executive summary, which includes a discussion of 1) how the research adds to the understanding of the area investigated; 2) the technical effectiveness and economic feasibility of the methods or techniques investigated or demonstrated; or 3) how the project is otherwise of benefit to the public. The discussion should be a minimum of one paragraph and written in terms understandable by an educated xxxxxx.
|
|
|
4.
|
Provide a comparison of the actual accomplishments with the goals and objectives of the project.
|
|
|
5.
|
Summarize project activities for the entire period of funding, including original hypotheses, approaches used, problems encountered and departure from planned methodology, and an assessment of their impact on the project results. Include, if applicable, facts, figures, analyses, and assumptions used during the life of the project to support the conclusions.
|
|
|
6.
|
Identify products developed under the award and technology transfer activities, such as:
|
|
|
a.
|
Publications (list journal name, volume, issue), conference papers, or other public releases of results. If not provided previously, attach or send copies of any public releases to the DOE Program Manager identified in Block 15 of the Assistance Agreement Cover Page;
|
|
|
b.
|
Web site or other Internet sites that reflect the results of this project;
|
|
|
c.
|
Networks or collaborations fostered;
|
|
|
d.
|
Technologies/Techniques;
|
|
|
e.
|
Inventions/Patent Applications, licensing agreements; and
|
|
|
f.
|
Other products, such as data or databases, physical collections, audio or
|
4
video, software or netware, models, educational aid or curricula, instruments or equipment.
|
|
7.
|
For projects involving computer modeling, provide the following information with the final report:
|
|
|
a.
|
Model description, key assumptions, version, source and intended use;
|
|
|
b.
|
Performance criteria for the model related to the intended use;
|
|
|
c.
|
Test results to demonstrate the model performance criteria were met
|
(e.g.,
code verification/validation, sensitivity analyses, history matching with lab or field data, as appropriate);
|
|
d.
|
Theory behind the model, expressed in non-mathematical terms;
|
|
|
e.
|
Mathematics to be used, including formulas and calculation methods;
|
|
|
f.
|
Whether or not the theory and mathematical algorithms were peer reviewed,
|
and, if so, include a summary of theoretical strengths and weaknesses;
|
|
g.
|
Hardware requirements; and
|
|
|
h.
|
Documentation (e.g., users guide, model code).
|
Electronic Submission. The final scientific/technical report must be submitted electronically-via the DOE Energy Link System (E-Link) accessed at xxxx://xxx.xxxx.xxx/xxxxx-0000.
Electronic Format. Reports must be submitted in the ADOBE PORTABLE DOCUMENT FORMAT (PDF) and be one integrated PDF file that contains all text, tables, diagrams, photographs, schematic, graphs, and charts. Materials, such as prints, videos, and books, that are essential to the report but cannot be submitted electronically, should be sent to the Contracting Officer at the address listed in Block 16 of the Assistance Agreement Cover Page.
Submittal Form. The report must be accompanied by a completed electronic version of DOE Form 241.3, “U.S. Department of Energy (DOE), Announcement of Scientific and Technical Information (STI).” You can complete, upload, and submit the DOE F.241.3 online via E-Link. You are encouraged not to submit patentable material or protected data in these reports, but if there is such material or data in the report, you must: (1) clearly identify patentable or protected data on each page of the report; (2) identify such material on the cover of the report; and (3) xxxx the appropriate block in Section K of the DOE F 241.3. Reports must not contain any limited rights data (proprietary data), classified information, information subject to export control classification, or other information not subject to release. Protected data is specific technical data, first produced in the performance of the award that is protected from public release for a period of time by the terms of the award agreement.
5
Conference Papers/Proceedings
Content: The recipient must submit a copy of any conference papers/proceedings, with the following information: (1) Name of conference; (2) Location of conference; (3) Date of conference; and (4) Conference sponsor.
Electronic Submission. Scientific/technical conference paper/proceedings must be submitted electronically-via the DOE Energy Link System (E-Link) at xxxx://xxx.xxxx.xxx/xxxxx-0000. Non-scientific/technical conference papers/proceedings must be sent to the URL listed on the Reporting Checklist.
Electronic Format. Conference papers/proceedings must be submitted in the ADOBE PORTABLE DOCUMENT FORMAT (PDF) and be one integrated PDF file that contains all text, tables, diagrams, photographs, schematic, graphs, and charts. If the proceedings cannot be submitted electronically, they should be sent to the DOE Administrator at the address listed in Block 16 of the Assistance Agreement Cover Page.
Submittal Form. Scientific/technical conference papers/proceedings must be accompanied by a completed DOE Form 241.3. The form and instructions are available on E-Link at xxxx://xxx.xxxx.xxx/xxxxx-0000. This form is not required for non-scientific or non-technical conference papers or proceedings.
Software/Manual
Content. Unless otherwise specified in the award, the following must be delivered: source code, the executable object code and the minimum support documentation needed by a competent user to understand and use the software and to be able to modify the software in subsequent development efforts.
Electronic Submission. Submissions may be submitted electronically-via the DOE Energy Link System (E-Link) at xxxx://xxx.xxxx.xxx/xxxxx/000-0xxx.xxx. They may also be submitted via regular mail to:
Energy Science and Technology Software Center
X.X. Xxx 0000
Xxx Xxxxx, XX 00000
Submittal Form. Each software deliverable and its manual must be accompanied by a completed DOE Form 241.4 “Announcement of U.S. Department of Energy Computer Software.” The form and instructions are available on E-Link at xxxx://xxx.xxxx.xxx/xxxxx/000-0xxx.xxx.
Protected Personally Identifiable Information (PII). Management Reports or Scientific/Technical Reports must not contain any Protected PII. PII is any information about an individual which can be used to distinguish or trace an individual’s identity. Some information that is considered to be PII is available in public sources such as telephone books, public websites, university listings, etc. This type of information is considered to be Public
6
PII and includes, for example, first and last name, address, work telephone number, e-mail address, home telephone number, and general educational credentials. In contrast, Protected PII is defined as an individual’s first name or first initial and last name in combination with any one or more of types of information, including, but not limited to, social security number, passport number, credit card numbers, clearances, bank numbers, biometrics, date and place of birth, mother’s maiden name, criminal, medical and financial records, educational transcripts, etc.
Recipients must complete the SF-425 as identified on the Reporting Checklist in accordance with the report instructions. A fillable version of the form is available at xxxx://xxx.xxxxxxxxxx.xxx/xxx/xxxxxx/xxxxxx_xxxxx.xxxx.
Final Invention and Patent Report
The recipient must provide a DOE Form 2050.11, “PATENT CERTIFICATION.” This form is available at xxxx://xxx.xxxxxxxxxx.xxx.xxx/xxxx/xxxxx/0000-00.xxx and xxxx://xxxxxxxxxx.xxxxxx.xxx/xxxxxxxx_xxx/xxxxxxxx_xxxxx.xxx
Property Certification
The recipient must provide the Property Certification, including the required inventories of non-exempt property, located at xxxx://xxx.xxxxxxxxxx.xxxxxx.xxx/xxxxxxxxx/XxxxxxxxXxxxXXXXX.xxx
Annual Indirect Cost Proposal and Reconciliation
Requirement. In accordance with the applicable cost principles, the recipient must submit an annual indirect cost proposal, reconciled to its financial statements, within six months after the close of the fiscal year, unless the award is based on a predetermined or fixed indirect rate(s), or a fixed amount for indirect or facilities and administration (F&A) costs.
Cognizant Agency. The recipient must submit its annual indirect cost proposal directly to the cognizant agency for negotiating and approving indirect costs. If the DOE awarding office is the cognizant agency, submit the annual indirect cost proposal to the URL listed on the Reporting Checklist.
Annual Inventory of Federally Owned Property
Requirement. If at any time during the award the recipient is provided Government-furnished property or acquires property with project funds and the award specifies that the property vests in the Federal Government (i.e. federally owned property), the recipient must submit an annual inventory of this property to
7
the URL listed on the Reporting Checklist no later than October 30th of each calendar year, to cover an annual reporting period ending on the preceding September 30th.
Content of Inventory. The inventory must include a description of the property, tag number, acquisition date, location of property, and acquisition cost, if purchased with project funds. The report must list all federally owned property, including property located at subcontractor’s facilities or other locations.
|
F.
|
AMERICAN RECOVERY AND REINVESTMENT ACT REPORTING
|
See Special Award Term entitled Reporting and Registration Requirements under Section 1512 of the Recovery Act. The reports are due no later than ten calendar days after each calendar quarter in which the recipient receives the assistance award funded in whole or in part by the Recovery Act. Additional information on complying with this requirement can be found at Department of Energy – OMB Reporting Help.
8
Applicant Name: FutureFuel Chemical Company Award Number: DE-EE0002532
Budget Information - Non Construction Programs
OMB Approval No. 0348-0044
|
Section A - Budget Summary
| | |
|
Grant Program Function or
Activity
(a)
|
Catalog of Federal
Domestic Assistance
Number
(b)
|
Estimated Unobligated Funds
|
New or Revised Budget
|
|
Federal
(c)
|
Non-Federal
(d)
|
Federal
(e)
|
Non-Federal
(f)
|
Total
(g)
|
|
1.
|
81.086
| | |
$12,600,000
|
$12,600,000
|
$25,200,000
|
|
2.
| | | | | |
$0
|
|
3.
| | | | | |
$0
|
|
4.
| | | | | |
$0
|
|
5. Totals
| |
$0
|
$0
|
$12,600,000
|
$12,600,000
|
$25,200,000
|
|
Section B - Budget Categories
| |
| |
Grant Program, Function or Activity
| |
| 6. Object Class Categories | (1) | (2) | (3) | (4) | Total (5) |
|
a. Personnel
|
$0
| |
$1,164,416
|
$1,164,415
|
$2,328,831
|
|
b. Fringe Benefits
| | | | |
$0
|
|
c. Travel
|
$0
| |
$8,500
|
$8,500
|
$17,000
|
|
d. Equipment
|
$0
| |
$1,210,891
|
$1,210,891
|
$2,421,782
|
|
e. Supplies
| | | | |
$0
|
|
f. Contractual
|
$0
| |
$3,300,528
|
$3,300,528
|
$6,601,056
|
|
g. Construction
|
$0
| |
$1,418,171
|
$1,418,171
|
$2,836,342
|
|
h. Other
|
$0
| |
$5,497,494
|
$5,497,495
|
$10,994,989
|
|
i. Total Direct Charges (sum of 6a-6h)
|
$0
|
$0
|
$12,600,000
|
$12,600,000
|
$25,200,000
|
|
j. Indirect Charges
| | | | |
$0
|
|
k. Totals (sum of 6i-6j)
|
$0
|
$0
|
$12,600,000
|
$12,600,000
|
$25,200,000
|
| | | | | | |
|
7. Program Income
| | | | |
$0
|
Previous Edition Usable
Page 1 of 4
SF-424A (Rev. 4-92)
Authorized for Local Reproduction
Prescribed by OMB Circular X-000
|
Xxxxxxx X - Xxx-Xxxxxxx Resources
| | |
|
(a) Grant Program
|
(b) Applicant
|
(c) State
|
(d) Other Sources
|
(e) Totals
|
|
8.
|
$6,780,071
| |
$5,819,929
|
$12,600,000
|
|
9.
| | | |
$0
|
|
10.
| | | |
$0
|
|
11.
| | | |
$0
|
|
12. Total (sum of lines 8 - 11)
|
$6,780,071
|
$0
|
$5,819,929
|
$12,600,000
|
|
Section D - Forecasted Cash Needs
| | | | |
| Total for 1st Year |
0xx Xxxxxxx
|
0xx Xxxxxxx
|
0xx Xxxxxxx
|
0xx Quarter
|
| 13. Federal $12,182,254 |
$3,045,563
|
$3,045,563
|
$3,045,564
|
$3,045,564
|
| 14. Non-Federal $12,182,255 |
$3,045,563
|
$3,045,564
|
$3,045,564
|
$3,045,564
|
| 15. Total (sum of lines 13 and 14) $24,364,509 |
$6,091,126
|
$6,091,127
|
$6,091,128
|
$6,091,128
|
|
Section E - Budget Estimates of Federal Funds Needed for Balance of the Project
| | | | |
|
(a) Grant Program
|
Future Funding Periods (Years)
|
|
(b) First
|
(c) Second
|
(d) Third
|
(e) Fourth
|
|
16.
|
$417,746
| | | |
|
17
| | | | |
|
18.
| | | | |
|
19.
| | | | |
|
20. Total (Sum of lines 16-19)
|
$417,746
|
$0
|
$0
|
$0
|
|
Section F - Other Budget Information
| | | | |
|
21. Direct Charges
|
22. Indirect Charges
|
|
23. Remarks
|
Previous Edition Usable
Page 2 of 4
SF-424A (Rev. 4-92)
Authorized for Local Reproduction
Prescribed by OMB Circular A-102
|
Instructions for the SF-424A
Public Reporting Burden for this collection of information is estimated to average 3.0 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Please do not return your completed form to the Office of Management and Budget; send it to the address provided by the sponsoring agency.
|
|
General Instructions
This form is designed so that application can be made for funds from one or more grant programs. In preparing the budget, adhere to any existing Federal grantor agency guidelines which prescribe how and whether budgeted amounts should be separately shown for different functions or activities within the program. For some programs, grantor agencies may require budgets to be separately shown by function or activity. For other programs, grantor agencies may require a breakdown by function or activity. Sections A, B, C, and D should include budget estimates for the whole project except when applying for assistance which requires Federal authorization in annual or other funding period increments. In the later case, Sections A, B, C, and D should provide the budget for the first budget period (usually a year) and Section E should present the need for Federal assistance in the subsequent budget periods. All applications should contain a breakdown by the object class categories shown in Lines a-k of Section B.
Section A. Budget Summary Lines 1-4 Columns (a) and (b)
For applications pertaining to a single Federal grant program (Federal Domestic Assistance Catalog number) and not requiring a functional or activity breakdown, enter on Line 1 under Column (a) the catalog program title and the catalog number in Column (b).
For applications pertaining to a single program requiring budget amounts by
multiple functions or activities, enter the name of each activity or function on each line in Column (a), and enter the catalog number in Column (b). For applications pertaining to multiple programs where none of the programs require a breakdown by function or activity, enter the catalog program title on each line in Column (a) and the respective catalog number on each line in Column (b).
For applications pertaining to multiple programs where one or more programs require a breakdown by function or activity, prepare a separate sheet for each program requiring the breakdown. Additional sheets should be used when one form does not provide adequate space for all breakdown of data required. However, when more than one sheet is used, the first page should provide the summary totals by programs.
Lines 1-4, Columns (c) through (g)
For new applications, leave Columns (c) and (d) blank. For each line entry in Columns (a) and (b), enter in Columns (e), (f), and (g) the appropriate amounts of funds needed to support the project for the first funding period (usually a year).
| |
For continuing grant program applications, submit these forms before the end of each funding period as required by the grantor agency. Enter in Columns (c) and (d) the estimated amounts of funds which will remain unobligated at the end of the grant funding period only if the Federal grantor agency instructions provide for this. Otherwise, leave these columns blank. Enter in columns (e) and (f) the amounts of funds needed for the upcoming period. The amount(s) in Column (g) should be the sum of amounts in Columns (e) and (f).
For supplemental grants and changes to existing grants, do not use Columns (c) and (d). Enter in Column (e) the amount of the increase or decrease of Federal funds
And enter in Column (f) the amount of the increase or decrease of non-Federal funds. In Column (g) enter the new total budgeted amount (Federal and non-Federal) which includes the total previous authorized budgeted amounts plus or minus, as appropriate, the amounts shown in Columns (e) and (f). The amount(s) in Column (g) should not equal the sum of amounts in Columns (e) and (f).
Line 5 - Show the totals for all columns used
Section B. Budget Categories..
In the column headings (a) through (4), enter the titles of the same programs,
Functions, and activities shown on Lines 1-4, Column (a), Section A. When
Additional sheets are prepared for Section A, provide similar column headings on each sheet. For each program, function or activity, fill in the total requirements for funds (both Federal and non-Federal) by object class categories.
Line 6a-l - Show the totals of Lines 6a to 6h in each column.
Line 6j - Show the amount of indirect cost.
Line 6k - Enter the total of amounts on Lines 6i and 6j. For all applications for new grants and continuation grants the total amount in column (5), Line 6k, should be the same as the total amount shown in Section A, Column (g), Line 5. For supplemental grants and changes to grants, the total amount of the increase or decrease as shown in Columns (1)-(4), Line 6k should be the same as the sum of the amounts in Section A, Columns (e) and (f) on Line 5.
Line 7 -Enter the estimated amount of income, if any, expected to be generated from this project. Do not add or subtract this amount from the total project amount. Show under the program narrative statement the nature and source of income. The estimated amount of program income may be considered by the federal grantor agency in determining the total amount of the grant.
|
Previous Edition Usable
Page 3 of 4
SF-424A (Rev. 4-92)
Authorized for Local Reproduction
Prescribed by OMB Circular X-000
|
Xxxxxxx X. Non-Federal Resources
Lines 8-11 - Enter amounts of non-Federal resources that will be used on the grant. If in-kind contributions are included, provide a brief explanation on a separate sheet.
Column (a) - Enter the program titles identical to Column (a), Section A. A breakdown by function or activity is not necessary.
Column (b) - Enter the contribution to be made by the applicant.
Column (c) - Enter the amount of the State’s cash and in-kind contribution if the applicant is not a State or State agency. Applicants which are a State or State agencies should leave this column blank.
| |
Section E. Budget Estimates of Federal Funds Needed for Balance of the
Project
Lines 16-19 - Enter in Column (a) the same grant program titles shown in Column
(a), Section A. A breakdown by function or activity is not necessary. For new applications and continuation grant applications, enter in the proper columns amounts of Federal funds which will be needed to complete the program or project over the succeeding funding periods (usually in years). This section need not be completed for revisions (amendments, changes, or supplements) to
Funds for the current year of existing grants.
If more than four lines are needed to list the program titles, submit additional schedules as necessary.
|
|
Column (d) - Enter the amount of cash and in-kind contributions to be made from all other sources.
| |
Line 20 - Enter the total for each of the Columns (b)-(e). When additional schedules are prepared for this Section, annotate accordingly and show the overall totals on this line.
|
|
Column (e) - Enter totals of Columns (b), (c), and (d).
Line 12- Enter the total for each of Columns (b)-(e). The amount in Column (e) should be equal to the amount on Line 5, Column (f) Section A.
Section D. Forecasted Cash Needs
Line 13 - Enter the amount of cash needed by quarter from the grantor agency during the first year.
| |
Section F. Other Budget Information
Line 21 - Use this space to explain amounts for individual direct object-class cost categories that may appear to be out of the ordinary or to explain the details as required by the Federal grantor agency.
Line 22 - Enter the type of indirect rate (provisional, predetermined, final or fixed) that will be in effect during the funding period, the estimated amount of the base to which the rate is applied, and the total indirect expense.
|
|
Line 14 - Enter the amount of cash from all other sources needed by quarter during the first year.
Line 15 - Enter the totals of amounts on Lines 13 and 14.
| |
Line 23 - Provide any other explanations or comments deemed necessary.
|
Previous Edition Usable
Page 4 of 4
SF-424A (Rev. 4-92)
Authorized for Local Reproduction
Prescribed by OMB Circular A-102
General Decision Number: AR100134 05/21/2010 AR134
Superseded General Decision Number: AR20080134
State: Arkansas
Construction Type: Building
Building Construction
County: Independence County in Arkansas.
BUILDING CONSTRUCTION PROJECTS (does not include single family
homes or apartments up to and including 4 stories).
Modification Number Publication Date
0 03/12/2010
1 03/19/2010
2 05/21/2010
BOIL0069-001 01/01/2009
Rates Fringes
BOILERMAKER $27.63 13.96
-------------------------------------------------------------------------------
ELEC1516-001 03/01/2010
Rates Fringes
ELECTRICIAN $22.46 10.01
-------------------------------------------------------------------------------
IRON0321-008 08/01/2009
Rates Fringes
IRONWORKER, STRUCTURAL $18.10 12.34
-------------------------------------------------------------------------------
* PLUM0155-008 09/22/2009
Rates Fringes
PIPEFITTER $23.51 7.75
-------------------------------------------------------------------------------
ROOF0020-018 01/01/2008
Rates Fringes
ROOFER $14.50 .20
-------------------------------------------------------------------------------
SFAR0669-001 01/01/2010
Rates Fringes
SPRINKLER FITTER (Fire $23.70 14.35
Sprinklers)
-------------------------------------------------------------------------------
SUAR2008-088 11/20/2008
Rates Fringes
BRICKLAYER $16.00 0.74
XXXXXXXXX, Including
Acoustical Ceiling
Installation, Drywall Hanging
and Form Work $13.00 5.36
CEMENT XXXXX/CONCRETE
FINISHER $13.47 2.53
IRONWORKER, REINFORCING $20.46 4.53
LABORER: Common or General $8.73 0.00
LABORER: Xxxxx Tender - Brick $9.25 0.00
OPERATOR: Backhoe/Excavator $12.50 1.97
OPERATOR: Bulldozer $11.08 0.00
OPERATOR: Crane $15.00 0.00
PAINTER: Brush, Roller and
Spray $12.43 0.00
PLUMBER $15.55 0.00
TRUCK DRIVER: Dump Truck $11.00 0.00
TRUCK DRIVER: Flatbed Truck $12.00 0.00
-------------------------------------------------------------------------------
WELDERS - Receive rate prescribed for craft performing
operation to which welding is incidental.
--------------------------------------------------------------------
Unlisted classifications needed for work not included within
the scope of the
classifications listed may be added after award only as
provided in the labor
standards contract clauses (29 CFR 5.5(a)(1)(ii)).
-------------------------------------------------------------------------------
In the listing above, the “SU” designation means that rates
listed under the
identifier do not reflect collectively bargained wage and
fringe benefit
rates. Other designations indicate unions whose rates have
been determined
to be prevailing.
-------------------------------------------------------------------------------
WAGE DETERMINATION APPEALS PROCESS
1.) Has there been an initial decision in he matter? This can
be:
* an existing published wage determination
* a survey underlying a wage determination
* a Wage and Hour Division letter setting forth a position on a wage
determination matter
* a conformance (additional classification and rate) ruling
On survey related matters, initial contact, including requests
for summaries
of surveys, should be with the Wage and Hour Regional Office
for the area in
which the survey was conducted because those Regional Offices
have
responsibility for the Xxxxx-Xxxxx survey program. If the
response from this
initial contact is not satisfactory, then the process described
in 2.) and
3.) should be followed.
With regard to any other matter not yet ripe for the formal process
described here, initial contact should be with the Branch of
Construction
Wage Determinations. Write to:
Branch of Construction Wage Determinations
Wage and Hour Division
U.S. Department of Labor
000 Xxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxxxx, XX 00000
2.) If the answer to the question in 1.) is yes, then an
interested party
(those affected by the action) can request review and
reconsideration from
the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR
Part 7).
Write to:
Wage and Hour Administrator
U.S. Department of Labor
000 Xxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxxxx, XX 00000
The request should be accompanied by a full statement of the
interested
party’s position and by any information (wage payment data),
project
description, area practice material, etc.) that the requestor
considers
relevant to the issue.
3.) If the decision of the Administrator is not favorable, an
interested
party may appeal directly to the Administrative Review Board
(formerly the
Wage Appeals Board). Write to:
Administrative Review Board
U.S. Department of Labor
000 Xxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxxxx, XX 00000
4.) All decisions by the Administrative Review Board are final.
END OF GENERAL DECISION
This document contains confidential information that has been omitted
and filed separately with the Securities and Exchange Commission.
Such information is noted by three asterisks, as follows “***.”
