[LOGO]
BUSINESS LOAN AGREEMENT
This Seafirst Business Loan Agreement ("Agreement") is made between
Seattle-First National Bank ("Bank") and The Coeur d'Alenes Company and Union
Iron Works, Inc. of Spokane, WA ("Borrower") with respect to the following:
PART A
I. Line of Credit # 1. Subject to the terms of this Agreement, Bank will make
loans to Borrower under a [x] revolving [ ] nonrevolving line of credit as
follows:
(a) TOTAL AMOUNT AVAILABLE: $ 1,850,000
[x] Subject to the provisions of any accounts receivable and/or inventory
borrowing plan required herein; it is expressly understood that
collateral ineligible for borrowing purposes is determined solely by
Bank.
[ ] Subject to (describe):________________________________________________
(b) AVAILABILITY PERIOD: March 26, 1996 through March 1, 1997. However, if
loans are made and/or new promissory notes executed after the last date,
such advances will be subject to the terms of this Agreement until repaid
in full unless a written statement signed by the Bank and Borrower provides
otherwise, ora replacement loan agreement is executed. The making of such
additional advances alone however, does not constitute a commitment by the
bank to make any further advances or extend the availability period.
(c) INTEREST RATE:
[x] Banks publicly announced prime rate plus 0.325 percent of the principal
per annum, adjusted on the date of any Bank prime rate change.
[ ] _______________________________________________________________________
(d) INTEREST RATE BASIS. All interest will be calculated at the per annum
interest rate based on 360-day year and applied to the actual number of days
elapsed.
(e) REPAYMENT: At the times and in amounts as set forth in note(s) required
under Part B Article 1 of this Agreement.
(f) LOAN FEE: $ 1,000.00 payable on March 26, 1996.
(g) FEE ON UNUTILIZED PORTION OF LINE: On N/A, and every N/A thereafter,
Borrower shall pay a fee based upon the average daily unused portion of the
line of credit. This fee will be calculated as follows:
(h) OTHER FEE(S) (IDENTIFY):___________________________________________________
___________________________________________________________________________
(i) COLLATERAL. This revolving line of credit shall be secured by a security
interest, which is hereby granted, in favor of Bank on the following
collateral: First lien position on accounts receivable and inventory. Also,
collateral securing other loans with Bank may secure this loan.
[logo]
BUSINESS LOAN AGREEMENT
1. Promissory Note(s). All loans shall be evidenced by promissory notes in a
form and substance satisfactory to Bank.
2. Conditions to Availability of Loan/Line of Credit. Before Bank is
obligated to disburse/make any advance, or at any time thereafter which Bank
deems necessary and appropriate, Bank must receive all of the following,
each of which must be in form and substance satisfactory to Bank loan
documents"):
2.1 Original, executed promissory note(s);
2.2 Original executed security agreement(s) and/or deed(s) of trust
covering the collateral described in Part A;
2.3 All collateral described in Part A in which Bank wishes to have a
possessory security interest;
2.4 Financing statement(s) executed by Borrower;
2.5 Such evidence that Bank may deem appropriate that the security
interests and liens in favor of Bank are valid, enforceable, and
prior to the rights and interests of others except those consented to
in writing by Bank;
+2.6 The following guaranty(ies) in favor of the Bank:
+2.7 Subordination agreement(s) in favor of Bank executed by:
2.8 Evidence that the execution, delivery, and performance by Borrower of
this Agreement and the execution, delivery, and performance by
Borrower and any corporate guarantor or corporate subordinating
creditor of any instrument or agreement required under this Agreement,
as appropriate, have been duly authorized;
2.9 Any other document which is deemed by the Bank to be required from
time to time to evidence loans or to effect the provisions of this
Agreement;
2.10 If requested by Bank, a written legal opinion expressed to Bank, of
counsel for Borrower as to the matters set forth in sections 3.1 and
3.2, and to the best of such counsel's knowledge after reasonable
investigation, the matters set forth in sections 3.3, 3.5, 3.6, 3.7,
3.8 and such other matters as the Bank may reasonably request;
2.11 Pay or reimburse Bank for any out-of-pocket expenses expended in
making or administering the loans made hereunder including without
limitation attorney's fees (including allocated costs of in-house
counsel);
+2.12 Other (describe):
3. Representations and Warranties. Borrower represents and warrants to Bank,
except as Borrower has disclosed to Bank in writing, as of the date of this
Agreement and hereafter so long as credit granted under this Agreement is
available and until full and final payment of all sums outstanding under
this Agreement and promissory notes that:
3.1 Borrower is duly organized and existing under the laws of the state
of its organization as a:
General Limited
X Corporation Partnership Partnership
--- --- ---
Sole
Proprietorship dba
--- ---
Borrower is properly licensed and in good standing in each state
in which Borrower is doing business and Borrower has qualified
under, and complied with, where required, the fictitious or trade
name statutes of each state in which Borrower is doing business,
and Borrower has obtained all necessary government approvals for
its business activities; the execution, delivery, and performance
of this Agreement and such notes and other instruments required
herein are within Borrower's powers, have been duly authorized,
and, as to Borrower and any guarantor, are not in conflict with the
terms of any charter, bylaw, or other organization papers of Borrower,
and this Agreement, such notes and the loan documents are valid and
enforceable according to their terms;
3.2 The execution, delivery, and performance of this Agreement, the loan
documents and any other instruments are not in conflict with any law
or any indenture, agreement or undertaking to which Borrower is a
party or by which Borrower is bound or affected;
3.3 Borrower has title to each of the properties and assets as reflected
in its financial statements (except such assets which have been sold
or otherwise disposed of in the ordinary course of business), and no
assets or revenues of the Borrower are subject to any lien except as
required or permitted by this Agreement, disclosed in its financial
statements or otherwise previously disclosed to Bank in writing;
3.4 All financial information, statements as to ownership of Borrower and
all other statements submitted by Borrower to Bank, whether previously
or in the future, are and will be true and correct in all material
respects upon submission and are and will be complete upon submission
insofar as may be necessary to give Bank a true and accurate knowledge
of the subject matter thereof;
3.5 Borrower has filed all tax returns and reports as required by law to
be filed and has paid all taxes and assessments applicable to Borrower
or to its properties which are presently due and payable, except those
being contested in good faith;
3.6 There are no proceedings, litigation or claims (including unpaid
taxes) against Borrower pending or, to the knowledge of the Borrower,
threatened, before any court or government agency, and no other event
has occurred which may have a material adverse effect on Borrower's
financial condition;
3.7 There is no event which is, or with notice or lapse of time, or both,
would be, an Event of Default (as defined in Section 7) under this
Agreement;
3.8 Borrower has exercised due diligence in inspecting Borrower's
properties for hazardous wastes and hazardous substances. Except as
otherwise previously disclosed and acknowledged to Bank in writing:
(a) during the period of Borrower's ownership of Borrower's
properties, there has been no use, generation, manufacture, storage,
treatment, disposal, release or threatened release of any hazardous
waste or hazardous substance by any person in, on, under or about any
of Borrower's properties; (b) Borrower has no actual or constructive
knowledge that there has been any use, generation, manufacture,
storage, treatment, disposal, release or threatened release of any
hazardous waste or hazardous substance by any person in, on, under or
about any of Borrower's properties by any prior owner or occupant of
any of Borrower's properties; and (c) Borrower has no actual or
constructive notice of any actual or threatened litigation or claims
of any kind by any person relating to such matters. The terms
'hazardous waste(s), hazardous substance(s),"disposal," "release,"
and threatened release as used in this Agreement shall have the same
meanings as set forth in the Comprehensive Environmental Response,
Compensation, and Liability Act of 1980, as amended, 42 U.S.C.
Section 9601, et seq., the Superfund Amendments and Re authorization
Act of 1986, as amended, Pub. L. No. 99-499, the Hazardous Materials
Transportation Act, as amended, 49 U.S. C. Section 1801, et seq.,
the Resource Conservation and Recovery Act, as amended, 49 U.S.C.
Section 6901, et seq., or other applicable state or federal laws,
rules or regulations adopted pursuant to any of the foregoing.
+3.9 Each chief place of business of Borrower, and the office or offices
where Borrower keeps its records concerning any of the collateral,
is located at:
4. Affirmative Covenants. So long as credit granted under this Agreement is
available and until full and final payment of all sums outstanding under
this Agreement and promissory note(s) Borrower will:
+4.1 Use the proceeds of the loans covered by this Agreement only in
connection with Borrower's business activities and exclusively for
the following purposes:
+4.2 Maintain current assets in an amount at least equal to 1.30 times
current liabilities, and not less than $ 1.000.000 in excess thereof.
Current assets and current liabilities shall be determined in
accordance with generally accepted accounting principles and
practices, consistently applied;
+4.3 Maintain a tangible net worth of at least S. 2,000,000 and not permit
Borrower's total indebtedness which is not subordinated in a manner
satisfactory to Bank to exceed 2.4 times Borrower's tangible net
worth. Tangible net worthy means the excess of total assets over total
liabilities, excluding, however, from the determination of total
assets (a) all assets which should be classified as intangible assets
such as goodwill, patents, trademarks, copyrights, franchises, and
deferred charges (including unamortized debt discount and research and
development costs), (b) treasury stock, (c) cash held in a sinking or
other similar fund established for the purpose of redemption or other
retirement of capital stock, (d) to the extent not already deducted
from total assets, reserves for depreciation, depletion, obsolescence
or amortization of properties and other reserves or appropriations of
hazardous wastes and hazardous substances contained in section 3.8, or
(ii) section 5.8. The provisions of this section 6 shall survive the full
and final payment of all sums outstanding under this Agreement and
promissory notes and shall not be affected by Bank's acquisition of any
interest in any of the Borrower's properties, whether by foreclosure or
otherwise.
7. EVENTS OF DEFAULT. The occurrence of any of the following events (events of
Default") shall terminate any and all obligations on the part of Bank to
make or continue the loan and/or line of credit and, at the option of Bank,
shall make all sums of interest and principal outstanding under the loan
and/or line of credit immediately due and payable, without notice of
default, presentment or demand for payment, protest or notice of non
payment or dishonor, or other notices or demands of any kind or character,
all of which are waived by Borrower, and Bank may proceed with collection
of such obligations and enforcement and realization upon all security which
it may hold and to the enforcement of all fights hereunder or at law:
7.1 The Borrower shall fail to pay when due any amount payable by it
hereunder on any loans or notes executed in connection herewith;
7.2 Borrower shall fail to comply with the provisions of any other
covenant, obligation or term of this Agreement for a period of
fifteen (15) days after the earlier of written notice thereof shall
have been given to the Borrower by Bank or Borrower or any
Guarantor has knowledge of an Event of Default or an event that can
become an Event of Default;
7.3 Borrower shall fail to pay when due any other obligation for
borrowed money, or to perform any term or covenant on its part to be
performed under any agreement relating to such obligation or any such
other debt shall be declared to be due and payable and such failure
shall continue after the applicable grace period;
7.4 Any representation or warranty made by Borrower in this Agreement or
in any other statement to Bank shall prove to have been false or
misleading in any material respect when made;
7.5 Borrower makes an assignment for the benefit of creditors, files a
petition in bankruptcy, is adjudicated insolvent or bankrupt,
petitions to any court for receiver or trustee for Borrower or any
substantial part of its property, commences any proceeding relating
to the arrangement, readjustment, reorganization or liquidation under
any bankruptcy or similar laws, or if there is commenced against
Borrower any such proceedings which remain undismissed for a period
of thirty (30) days or, if Borrower by any act indicates its consent
or acquiescence in any such proceeding or the appointment of any such
trustee or receiver;
+7.6 Any judgment attaches against Borrower or any of its properties for an
amount in excess of $25,000 which remains unpaid, unstayed on appeal,
unbonded, or undismissed for a period of thirty (30) days;
7.7 Loss of any required government approvals, and/or any governmental
regulatory authority takes or institutes action which, in the opinion
of Bank, will adversely affect Borrower's condition, operations or
ability to repay the loan and/or line of credit;
7.8 Failure of Bank to have a legal, valid and binding first lien on, or
a valid and enforceable prior perfected security interest in, any
property covered by any deed of trust or security agreement required
under this Agreement;
7.9 Borrower dies, becomes incompetent, or ceases to exist as a going
concern;
7.10 Occurrence of an extraordinary situation which gives Bank reasonable
grounds to believe that Borrower may not, or will be unable to,
perform its obligations under this or any other agreement between Bank
and Borrower; or
7.11 Any of the preceding events occur with respect to any guarantor of
credit under this Agreement, or such guarantor dies or becomes
incompetent, unless the obligations arising under the guaranty and
related agreements have been unconditionally assumed by the
guarantor's estate in a manner satisfactory to Bank.
8. SUCCESSORS; WAIVERS. Notwithstanding the Events of Default above, this
Agreement shall be binding upon and inure to the benefit of Borrower
and Bank, their respective successors and assigns, except that
Borrower may not assign its rights hereunder. No consent or waiver
under this Agreement shall be effective unless in writing and signed by
the Bank and shall not waive or affect any other default, whether prior
or subsequent thereto, and whether of the same or different type. No
delay or omission on the part of the Bank in exercising any right shall
operate as a waiver of such right or any other right.
9. Arbitration.
9.1 At the request of either Bank or Borrower any controversy or claim
between the Bank and Borrower, arising from or relating to this
Agreement or any Loan Document executed in connection with this
Agreement or arising from any alleged tort shalt be settled by
arbitration in King County Washington. The United States Arbitration
Act will apply to the arbitration proceedings which will be
administered by the American Arbitration Association under its
commercial rules of arbitration except that unless the amount of
the claim(s) being arbitrated exceeds $5,000,000 there shall be only
one arbitrator. Any controversy over whether an issue is arbitrable
shall be determined by the arbitrator(s). Judgment upon the
arbitration award may be entered in any court having jurisdiction.
The institution and maintenance of any action for judicial relief
or pursuit of a provisional or ancillary remedy shall not constitute
a waiver of the fight of either party, including plaintiff, to submit
the controversy or claim to arbitration if such action for judicial
relief is contested.
For purposes of the application of the statute of limitations the
filing of an arbitration as provided herein is the equivalent of
filing a lawsuit and the arbitrator(s) will have the authority to
decide whether any claim or controversy is barred by the statute of
limitations, and if so, to dismiss the arbitration on that basis.
The parties consent to the joinder in the arbitration proceedings of
any guarantor, hypothecator or other party having an interest related
to the claim or controversy being arbitrated.
9.2 Notwithstanding the provisions of Section 9.1, no controversy or
claim shall be submitted to arbitration without the consent of all
parties if at the time of the proposed submission, such controversy
or claim arises from or relates to an obligation secured by real
property;
9.3 No provision of this Section 9 shall limit the right of the Borrower
or the Bank to exercise self-help remedies such as setup foreclosure
or sale of any collateral, or obtaining any ancillary provisional or
interim remedies from a court of competent jurisdiction before, after
or during the pendency of any arbitration proceeding. The exercise of
any such remedy does not waive the right of either party to request
arbitration. At Bank's option foreclosure under any deed of trust may
be accomplished by exercise of the power of sale under the deed of
trust or judicial foreclosure as a mortgage.
10. COLLECTION ACTIVITIES, LAWSUITS AND GOVERNING LAW. Borrower agrees to pay
Bank all costs and expenses (including reasonable attorney's fees and the
allocated cost for in-house legal services incurred by Bank), to enforce
this Agreement, any notes or any Loan Documents pursuant to this Agreement,
whether or not suit is instituted. If suit is instituted by Bank to enforce
this Agreement or any of these documents, Borrower consents to the personal
jurisdiction of the Courts of the State of Washington and Federal Courts
located in the State of Washington. Borrower further consents to the venue
of this suit, being laid in King County, Washington. This Agreement and any
notes and security agreements entered into pursuant to this Agreement shall
be construed in accordance with the laws of the State of Washington.
+11. ADDITIONAL PROVISIONS. This Agreement supersedes all oral negotiations or
agreements between Bank and Borrower with respect to the subject matter
hereof and constitutes the entire understanding and Agreement of the
matters set forth in this Agreement.
11.1 If any provision of this Agreement is held to be invalid or
unenforceable,then (a) such provision shall be deemed modified if
possible, or if not possible, such provision shall be deemed
stricken, and (b) all other provisions shall remain in full force
and effect.
11.2 If the imposition of or any change in any law, rule, or regulation
guideline or the interpretation or application of any thereof by any
court of administrative or governmental authority (including any
request or policy whether or not having the force of law) shall
impose or modify any taxes (except U.S. federal, state or local
income or franchise taxes imposed on Bank), reserve requirements,
capital adequacy requirements or other obligations which would: (a)
increase the cost to Bank for extending or maintaining any loans
and/or line of credit to which this Agreement relates, (b) reduce
the amounts payable to Bank under this Agreement, such notes and
other instruments, or (c) reduce the rate of return on Bank's
capital as a consequence of Bank's obligations with respect to any
loan and/or line of credit to which this Agreement relates, then
Borrower agrees to pay Bank such additional amounts as will
compensate Bank therefor, within five (5) days after Bank's written
demand for such payment, which demand shall be accompanied by an
explanation of such imposition or charge and a calculation in
reasonable detail of the additional amounts payable by Borrower,
which explanation and calculations shall be conclusive, absent
manifest error.
11.3 Bank may sell participations in or assign this loan in whole
or in part without notice to Borrower and Bank may provide
information regarding the Borrower and this Agreement to any
prospective participant or assignee. If a participation is sold or
the loan is assigned the purchaser will have the
right of set off against the Borrower and may enforce its interest
in the Loan irrespective of any claims or defenses the Borrower may
have against the Bank.
12. NOTICES. Any notices shall be given in writing to the opposite
party's signature below or as that party may otherwise specify in
writing.
13. ORAL AGREEMENTS OR ORAL COMMITMENTS T O LOAN MONEY. EXTEND CREDIT.
OR TO FORBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT ENFORCEABLE
UNDER WASHINGTON LAW.
This Business Loan Agreement (Parts A and B) executed by the parties on March
26, 1996. Borrower acknowledges having read all of the provisions of this
Agreement and Borrower agrees to its terms.
SEATTLE-FIRST NATIONAL BANK S & E Commercial Team #1
________________________
(Branch/Office)
By: /s/ Xxxxx X. Xxxx Title: Vice President
____________________________ ______________
Address: X.X.Xxx 1446 City,State,Zip: Xxxxxxx, XX 00000
____________ _________________
Phone: (000) 000-0000 Fax: (000) 000-0000
_____________ ______________
The Coeur d'Alenes Company and Union Iron Works. Inc. of Spokane. WA
____________________________________________________________________
(Borrower Name)
By: /s/ Xxxxxxx Xxxxxxxxx Title: Treasurer
______________________________ _________
Address: P. O. Box 2610 City,State, Zip: Xxxxxxx. XX 00000
______________ _________________
Phone: (000) 000-0000 Fax: (000) 000-0000
______________ ______________
[LOGO]
Loan No. 604938 and 453817-9
PROMISSORY NOTE
$1,688,000.00 December 20, 0000
Xxxxxxx, Xxxxxxxxxx
FOR VALUE RECEIVED, the undersigned ("Maker") promise(s) to pay to the order
of SEATTLE-FIRST NATIONAL BANK, a national banking association ("Lender"), at
its principal office in Seattle, Washington, or at such other place or places
or to such other party as the "molder" (defined below) of this Note may from
time to time designate in writing, the principal sum of ONE MILLION SIX
HUNDRED EIGHTY-EIGHT THOUSAND AND NO/00 DOLLARS ($ 1,688,000.00), or so much
thereof as may be advanced, in lawful money of the United States of America,
together with interest thereon, on the following agreements, terms and
conditions. The term "Holder" as used in this Note means Lender or any future
holder of this Note, and their successors and assigns.
1. TERM. This Note shall have an initial term (the "CONSTRUCTION TERM")
expiring ten (10) months from the first day of the first calendar month
following the initial advance by the Holder under this Note. The last day of
the Construction Term is referred to in this Note as the "MATURITY DATE". If
Maker is not then in default under this Note or any other documents or
instruments executed by Maker in connection with the loan (the "LOAN")
evidenced by this Note (collectively with this Note, the "LOAN DOCUMENTS"),
on or before the last day of the Construction Term, the Loan shall convert to
a permanent loan (the "PERMANENT LOAN") if Maker has complied with the
following conditions, and with all other conditions as may be specified in
any other Loan Document:
(a) Maker shall have provided the Holder with current financial
statements of Maker, any general partner in Maker and any guarantor of the
Loan, each certified as correct by the appropriate party, showing no material
adverse change in any such person's or entity's financial condition from the
date of this Note, and otherwise acceptable to the Holder in its sole
discretion;
(b) Maker is not then in default under this Note or any other Loan Document,
(c) The improvements to be constructed with the proceeds of the Loan
shall have been completed in accordance with the plans and specifications for
the improvements approved by Lender and a certificate of occupancy shall have
been issued by the applicable governmental authority allowing the use and
occupancy of the improvements for their intended purposes; and
(d) Maker shall have complied with such other conditions to the
conversion as the Holder may reasonably require and specify in writing prior
to the date of the conversion.
If the Loan is converted to the Permanent Loan as provided above, the
Maturity Date shall be extended to that date which is one hundred twenty
(120) months from the first day of the first calendar month following the
date of the conversion unless otherwise agreed in writing by the Holder.
2. INTEREST. Interest shall commence to run on each advance under this
Note from the date of the advance and will be computed on the outstanding
balance of this Note as it exists from time to time at the interest rates
provided for in subparagraphs 2(a) and 2(b) below, as applicable. After
maturity, or after default, interest shall accrue on the outstanding
principal balance of this Note at an interest rate equal to four percentage
points (4%) per annum above the interest rate otherwise applicable to this
Note.
(a) CONSTRUCTION TERM INTEREST. During the Construction Term, the
principal balance of this Note shall bear interest at a per annum interest
rate equal to the sum of the publicly
announced prime rate (the "PRIME RATE") of Lender, as the same may change
from time to time, plus three hundred twenty-five one- thousandths of one
percentage point (0.325%) per annum. Interest rate adjustments caused by
changes to the Prime Rate shall be effective the same day as the adjustments
to the Prime Rate are effective. Interest on this Note during the
Construction Term shall be computed on the basis of a 360-day year and the
actual number of days elapsed in the period for which interest is payable.
(b) PERMANENT LOAN INTEREST. If the Loan converts to the Permanent Loan,
interest shall accrue on the principal balance of this Note either at a
variable interest rate as provided in subparagraph 2(b)(i) below (the
"VARIABLE RATE"), or at a fixed interest rate as provided in subparagraph
2(b)(ii) below (the "FIXED RATE"). After conversion to the Permanent Loan,
interest on this Note shall be calculated using a 30-day month and a 360-day
year.
(i) VARIABLE RATE. Unless Maker elects to have interest calculated at
the Fixed Rate pursuant to subparagraph 2(b)(ii) below, interest shall accrue
on the principal balance of this Note at the Variable Rate. The initial
Variable Rate shall be equal to the "LIBOR INDEX" (defined below) as of the
date the Loan converts to the Permanent Loan, plus two and three-fourths
percentage points (2.750%) per annum, rounded to the next highest one-eighth
of one percent (0.125%). The Variable Rate, if applicable, will change five
(5) months after the first payment date stated in subparagraph 3(b) below,
and every sixth (6th) month thereafter (each such date being referred to in
this Note as an "INTEREST CHANGE DATE").
(1) LIBOR Index - Current Index - Changes in the Variable Rate
will be based on changes in the 180-day LIBOR as defined below (the "LIBOR
Index"). If the LIBOR Index is no longer available, the Holder will choose a
new index based upon comparable information and give Maker notice of the
choice. The most recently available LIBOR Index fifteen (15) Business Days
before each Interest Change Date is the "Current Index" .
(2) Calculation of Variable Rate - Before each Interest Change
Date, if applicable, the Holder will calculate the new Variable Rate which
shall be equal to the Current Index, plus two and three-fourths percentage
points (2.750%) per annum, rounded to the next highest one-eighth of one
percent (0.125%). This new interest rate will be the Variable Rate until the
next Interest Change Date.
(3) LIBOR means the London Interbank Offer Rate, adjusted at the
Holder's option for statutory reserves, deposit insurance, regulatory
capital, taxes and assessments, if any, and is the average of the rates of
interest, on a per annum basis, at which deposits in United States dollars
having a term of 180 days are offered by major banks in immediately available
funds to prime banks in the London Interbank market at 11:00 A.M. (London
time) on the date the Loan converts to a Permanent Loan, for the day which is
fifteen (15) Business Days prior to the applicable Interest Change Date, as
applicable. This rate is reported on Telerate, a national and international
medium which provides interest rate quotations daily, as quoted by the
British Bankers Association as Interest Settlement Rates on page 3750 (or
such other page as may replace it). Such interest rate quotation, as provided
by Telerate, shall be deemed conclusive and final with respect to LIBOR
determinations for so long as Telerate continues to make such interest rate
reports. If Telerate or the British Bankers Association report is no longer
available for 180-day maturities, a comparable publication or report
containing such information selected by the Holder will be used. If there is
no such publication or comparable publication containing such information,
the 180-day LIBOR shall be the average rate (rounded if necessary to the
nearest one-thousandth of a percent) at which dollar deposits having a
maturity of 180 days are offered by at least two major banks in an interbank
market where Eurodollars are being traded to prime banks in immediately
available funds on the LIBOR determination date described above or as soon
thereafter as such offer quotes can be obtained.
(4) Business Day means a day on which commercial banks are
generally open for business in Seattle, Washington and London, England.
(5) The amount of adjustment for reserves, deposit insurance,
regulatory capital, taxes and assessments may change on any Interest Change
Date depending on such charges then being assessed against the Holder. Such
charges may change due to various factors,
2
including but not limited to, changes in the requirements for reserves and
capital adequacy promulgated by the Federal Reserve System of the United
States and/or other state and federal regulatory agencies, statutory changes
affecting the Holder, and/or imposition of taxes, FDIC fees and/or
assessments. Each determination of an adjustment amount shall be made by the
holder in its sole and absolute discretion and shall be conclusive and
binding upon Maker and shall be determined without benefit of or credit for
prorations, exceptions or offsets that may be available to the Holder frown
time to time.
(ii) FIXED RATE. Prior to the date the Loan converts to the Permanent
Loan, Maker may elect by written notice to the Holder to have interest on the
entire principal amount of this Note calculated for the entire term of the
Permanent Loan at a Fixed Rate, as provided below. Further, so long as Maker
is not in default under the terms of this Note or any Loan Document, at any
time after the Loan converts to the Permanent Loan, Maker at its option, and
upon the payment of a fee to the Holder equal to 0.250% of the then
outstanding principal balance of this Note (or $500.00, whichever is
greater), may elect by written notice to the Holder to have interest
calculated on the entire principal balance of this Note at a Fixed Rate
calculated as provided below for the remainder of the term of the Permanent
Loan. Maker's ability to fix the interest rate on this Note pursuant to this
subparagraph 2(b)(ii) is subject to the availability to the Holder of
matchfunding opportunities for a time period equivalent to the term of this
Note following the date of Maker's election to fix the interest rate.
(1) Calculation of Fixed Rate - If Maker elects to have a Fixed
Rate apply to this Note, interest shall accrue on the principal balance of
this Note at a per annum rate equal to Lender's reserve adjusted "FIXED RATE
INDEX" as quoted by Lender on the date the interest rate is converted to the
Fixed Rate, for a period equivalent to the term of the Permanent Loan (or
remainder thereof, as applicable), plus two and thirty-three one-hundredths
percentage points (2.330%) per annum, rounded upward to the next highest
one-eighth of one percent (0.125%). The Fixed Rate Index may be adjusted at
the Holder's option to reflect statutory reserves, deposit insurance,
regulatory capital, taxes and assessments, if any, as set forth in
subparagraph 2(b)(i)(5) above.
(2) Date of Conversion - The interest rate will be converted to
the Fixed Rate on the date the Holder receives Maker's written notice
electing the Fixed Rate option, provided such notice is received before noon,
Seattle time, on a Business Day, and the fee payable in connection with the
election has been received by Holder. If notice is received by Holder after
noon, Seattle time, on a Business Day, the interest rate applicable to this
Note will convert to a Fixed Rate on the next Business Day. For purposes of
this subparagraph 2(b)(ii)(2) only, the term "BUSINESS DAY" means a day on
which commercial banks are generally open for business in Seattle,
Washington.
3. PAYMENTS.
(a) CONSTRUCTION TERM PAYMENTS. During the Construction Term, Maker
shall make monthly payments of interest on this Note as it accrues. Payments
shall be due on the first day of each calendar month during the Construction
Term, commencing on the first day of the first calendar month following the
initial advance by the Holder under this Note.
(b) PERMANENT LOAN PAYMENTS. If the Loan converts to the Permanent
Loan, Maker shall make monthly payments of principal and interest to the
Holder, in amounts sufficient to fully amortize the principal balance of this
Note over a twenty (20) year amortization period in substantially equal
payments, based on the interest rate applicable to this Note, calculated as
provided below. Such monthly payments of principal and interest shall be due
on the first day of each calendar month during the term of the Permanent
Loan, commencing on the first day of the second calendar month following the
month in which the Loan converts to the Permanent Loan. The monthly payments
required on this Note following conversion to the Permanent Loan shall be
calculated as follows:
(i) VARIABLE RATE PAYMENTS. If interest is accruing on this Note
at a Variable Rate, the amount of the initial monthly payments shall be in an
amount sufficient to fully amortize the principal balance of this Note at the
initial Variable Rate, in substantially equal monthly
3
payments over the amortization period specified above. Promptly after the
Loan converts to the Permanent Loan, the Holder will provide Maker with a
closing statement (or other written notice) which will confirm the initial
Variable Rate and the amount of the initial principal and interest payments
due under this Note. The monthly payment will change after each Interest
Change Date to an amount sufficient to repay the then unpaid principal
balance of this Note in full at the then current interest rate, in
substantially equal monthly payments over the balance of the amortization
period specified above. Until the payment is again changed, Maker shall pay
the new monthly payment each month beginning on the first day of the first
calendar month after the applicable Interest Change Date. The Holder will
mail or deliver to Maker a notice of any changes in the interest rate
applicable to this Note, and any resulting changes in the monthly payments
required under this Note, prior to the date the first payment is due after
the applicable Interest Change Date.
(ii) FIXED RATE PAYMENTS. If interest is accruing on this Note at a
Fixed Rate, the amount of the monthly payments shall be in an amount
sufficient to fully amortize the principal balance of this Note at the
applicable Fixed Rate, in substantially equal monthly payments over the
amortization period specified above, or the remainder thereof, as applicable.
The applicable Fixed Rate and the amount of the monthly principal and
interest payments due under this Note shall be confirmed in writing by the
Holder (either pursuant to a closing statement or other written notice) after
the interest rate is Fixed and prior to the date the first payment is due at
the Fixed Rate.
(c) GENERAL. At the option of the Holder, all payments under this
Note, including payment at maturity, shall be made in same day funds. On the
Maturity Date (as the same may be extended as provided in this Note), the
unpaid principal balance of this Note, all unpaid accrued interest and all
other sums then due and owing pursuant to this Note or any other Loan
Document shall be due and payable in full. Each payment shall be applied
first, at Holder's option, to any unpaid late charges or other sums payable
by Maker under this Note or any other Loan Document, then to interest to the
due date of the payment, and then to the principal balance of this Note.
4. AUTOMATIC WITHDRAWAL. The payments on this Note and any other sums
secured by the Deed of Trust Will be deducted on the first (lst) day of each
month from Seafirst Deposit Account No. 00000000, or such other Seafirst
Deposit Account as may be authorized in the future.
5. LATE CHARGES; RETURNED ITEM FEE. If any payment due hereunder is not
received by the Holder within fifteen (15) days of the due date, at the
option of the Holder without waiving such default or any of its remedies, a
late charge shall be added to the delinquent payment in the amount of four
percent (4%) of the full payment not timely paid. Any such late charge shall
be due and payable on demand, and the Holder, at its option, may (a) refuse
any late payment or any subsequent payment unless accompanied by the
applicable late charge, (b) add the late charge to the principal balance of
this Note, (c) pay any late charge with advances of the undisbursed proceeds
of the Loan, if any, or (d) treat the failure to pay the late charge as
demanded as a default under this Note. If a late charge is added to the
principal balance of this Note, it shall bear interest at the same rate as
the principal balance of this Note. Any payment to Holder by check, draft or
other item shall be received by Holder subject to collection and will
constitute payment when collected not when received. For each "nsf" or
returned check, draft or other item, in addition to any applicable late
charge, Maker shall pay to the Holder on demand a returned item fee in
accordance with the Holder's schedule of such fees then in effect.
6. PREPAYMENT. During the Construction Term, and thereafter, so long as
interest is calculated on this Note at a Variable Rate, this Note may be
prepaid in whole or in part, at any time, without payment of a prepayment
fee. During any period when a Fixed Rate is applicable to this Note, this
Note may be prepaid only as set forth in EXHIBIT A attached. Partial
prepayments, if permitted, shall not postpone nor reduce the amount of the
monthly payments required under this Note.
7. DEFAULT. After a default under any of the Loan Documents, or if Maker
fails to make any payment under this Note when due, the Holder, at its
option, without notice to Maker (except as provided below), may declare the
entire principal balance of this Note and all unpaid accrued interest thereon
and other charges payable by Maker pursuant to this Note or any other Loan
4
Document immediately due and payable in full, and the Holder may exercise any
and all other rights or remedies available to it under any Loan Document, at
law or in equity. Any additional interest due because of a default shall
accrue from the date of default and shall be paid as a condition to the
curing of the default. Notwithstanding the foregoing, the Holder will not
accelerate the Maturity Date (a) because of a monetary default by Maker under
this Note or any other Loan Document unless the default is not cured within
ten (10) days of the date on which the Holder mails or delivers written
notice of the default to Maker, or (b) because of a nonmonetary default by
Maker under this Note or any other Loan Document unless the default is not
cured within thirty (30) days of the date on which the Holder mails or
delivers written notice of the default to Maker. For purposes of this Note,
the term "monetary default" means a failure by Maker to make any payment
required pursuant to this Note or any other Loan Document, and the term
"nonmonetary default" shall mean a failure by Maker to perform any obligation
contained in this Note or any other Loan Document, other than the obligation
to make the payments provided for in this Note or any other Loan Document. If
the nonmonetary default is capable of being cured and cannot reasonably be
made within the thirty (30) day cure period, the cure period shall be
extended up to ninety (90) days so long as Maker has commenced action to cure
within the thirty (30) day cure period, and in the Holder's opinion, Maker is
proceeding to cure the default with due diligence. None of the foregoing
shall be construed to obligate the Holder to forbear in any other manner from
exercising its remedies and the Holder may pursue any other rights or
remedies which the Holder may have because of the default.
8. CUMULATlVE REMEDIES. The rights and remedies of any Holder under this
Note or any other Loan Document, or at law or in equity, shall be cumulative
and concurrent, may be pursued singly, successively or together against
Maker, any guarantor of this Note, or any security for this Note. A failure
by any Holder to exercise its option to accelerate this Note upon the
occurrence of a default or to exercise any other rights to which it may be
entitled shall not constitute a waiver of the right to exercise such option
or any such rights in the event of any subsequent default, whether of the
same or a different nature.
9. WAIVERS. Maker and all endorsers, guarantors and all other persons or
entities who may become liable for all or any part of the obligations
evidenced by this Note, jointly and severally: waive diligence, presentment,
protest and demand, and also notice of protest, demand, non-payment, dishonor
or maturity and also recourse to suretyship defenses generally; and consent
to any and all renewals, extensions and modifications of the terms of this
Note or any other Loan Document, including the time for payment, and agree
any such renewal, extension or modification or the release or substitution of
any security for the indebtedness evidenced by this Note or any other
indulgences, shall not affect the liability of said parties for the
indebtedness evidenced by this Note. Any such renewals, extensions,
modifications, releases or indulgences may be made without notice to such
parties.
10. COSTS AND EXPENSES. Whether or not suit is brought Maker shall pay on
demand all costs and expenses, including attorneys' fees and costs and
allocated costs of in-house legal counsel, incurred by or on behalf of the
Holder in connection with this Note, including without limitation costs
incurred in the collection of this Note, in protecting the security for this
Note or in foreclosing or enforcing this Note or any other Loan Document, or
resulting from the Holder being made a party to any litigation because of the
existence of this Note or any other Loan Document. Without limiting the
generality of the foregoing, if Maker becomes the subject of any bankruptcy
or insolvency proceeding, Maker shall pay all fees and expenses incurred by
the Holder in connection with such bankruptcy or insolvency proceeding.
11. MAXIMUM INTEREST. Maker represents and warrants the proceeds of this
Note shall be used solely for commercial, investment and business purposes,
and not for personal, family or household purposes. Notwithstanding any other
provision of this Note or any other Loan Document, interest, loan fees and
charges payable by reason of the indebtedness evidenced by this Note shall
not exceed the maximum, if any, permitted by applicable law. If by virtue of
applicable law, sums in excess of such maximum would otherwise be payable,
then such excess sums shall be construed as having been immediately applied
by the Holder to the principal balance of this Note when received. If at the
time any such sum is received by the Holder, the principal balance of this
Note has been paid in full, such sums shall be promptly refunded by the
Holder to Maker, less any sums due to the Holder.
5
12. SECURITY. This Note is secured by a deed of trust of even date (the
"Deed of Trust") encumbering certain real property located in Spokane County,
Washington (the "Property"). Unless otherwise specified in this Note, all
notices given pursuant to this Note must be in writing and will be
effectively given if given in accordance with the terms of the Deed of Trust.
13. GENERAL. This Note shall be binding upon Maker and Maker's
beneficiaries, heirs, devisees, personal representatives, successors and
assigns. If Maker consists of more than one person or entity, all of such
persons and entities shall be jointly and severally liable for Maker's
obligations under this Note. This Note is governed by and shall be construed
in accordance with the laws of the State of Washington. Each person or entity
executing this Note consents to the non-exclusive personal jurisdiction and
venue of the courts of the State of Washington and the United States federal
courts located therein, in any action relating to or arising out of the
enforcement or interpretation of this Note or any other Loan Document. Each
such person or entity further agrees not to assert in any such action that
the proceeding has been brought in an inconvenient forum.
14. ARBITRATION. Any dispute relating to this Note or the Loan (whether
in contract or tort) shall be settled by arbitration if requested by Maker,
the Holder or any other party to the dispute (such as a guarantor); provided,
both Maker and the Holder must consent to a request for arbitration relating
to an obligation secured by real property. The arbitration proceedings shall
be held in Seattle, Washington in accordance with the commercial arbitration
rules of the American Arbitration Association, and the United States
Arbitration Act (i.e., Title 9, U.S.C.). There shall be one arbitrator who
shall decide whether an issue is arbitrable or whether any claim is barred by
a statute of limitations. Judgment on the arbitration award may be entered in
any court having jurisdiction. Commencement of a lawsuit shall not constitute
a waiver of the right of any party to request arbitration if the lawsuit is
contested. Each party shall have the right before, during and after the
commencement of any arbitration proceeding to exercise any of the following
remedies, in any order or concurrently: (i) self-help remedies such as setoff
or repossession; (ii) judicial or nonjudicial foreclosure against real or
personal property collateral; and (iii) provisional remedies including
injunction, appointment of receiver, attachment, claim and delivery and
replevin. The exercise of any such remedy shall not waive a party's right to
request arbitration. Nothing in this paragraph shall limit in any way any
right the Holder may have to foreclose the Deed of Trust judicially as a
mortgage, or nonjudicially pursuant to the power of sale.
15. DISPUTED OBLIGATIONS. All communications concerning disputed debts
and obligations of Maker under this Note or any other Loan Document,
including without limitation disputes as to the amount of any payment, fee or
charge, and including an instrument tendered as full satisfaction of a
disputed debt, must be in writing and must be sent to the following address,
or to such other address as the Holder may hereafter specify:
Seattle-First National Bank
Attention: Loan Servicing Manager
Real Estate Group (CSC-14)
000 Xxxxx Xxxxxx, Xxxxx 00
Xxxxxxx, Xxxxxxxxxx 00000
Any such communication should include the name of Maker, the applicable loan
number, a description of the dispute and the relief or remedy requested, and
an address and telephone number where the person sending the notice can be
contacted.
NOTICE: ORAL AGREEMENTS OR ORAL COMMITMENTS TO LOAN MONEY, EXTEND CREDIT OR
FORBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT ENFORCEABLE UNDER
WASHINGTON LAW.
MAKER:
THE COEUR D'ALENES COMPANY, an Idaho corporation
By: Xxxxxxx Xxxxxxxxx
------------------
Its: Treasurer
------------------
EXHIBIT A
---------
PREPAYMENT
If the interest rate converts to the Fixed Rate the principal balance of
this Note may be prepaid in whole or in part, at any time provided (i) a
prepayment fee is paid as set forth below, (ii) each partial repayment is in
an amount of $10,000.00 or more, and (iii) partial prepayments may be no more
frequent than once per month. THE PREPAYMENT FEE SHALL BE DUE AND PAYABLE
WHETHER THE PREPAYMENT IS BY VOLUNTARY PREPAYMENT, OPERATION OF LAW,
ACCELERATION OR OTHERWISE. The amount of the prepayment fee depends on the
following:
l . The amount by which certain "REFERENCE RATES", as defined below,
have changed between the time this Note is prepaid and the date the interest
rate converts to the Fixed rate.
2. A prepayment fee factor (see "PREPAYMENT FEE FACTOR SCHEDULE"
below).
3. The amount of principal prepaid.
DEFINITION OF REFERENCE RATES
The "REFERENCE RATE" used to represent interest rate levels shall be the
bond equivalent yield of the average US Treasury Securities having maturities
equivalent to the remaining period to maturity of the Loan, rounded upward to
the nearest month. The "INITIAL REFERENCE RATE" shall be the Reference Rate
assigned to the Loan by the Holder at the time the interest rate converts to
the Fixed Rate. The "FINAL REFERENCE RATE" shall be the Reference Rate
assigned to the Loan by the Holder at the time of the prepayment.
The applicable Reference Rates shall be determined from the Federal
Reserve Statistical Release (Publication H.15) as displayed on Page 119 of
the Dow Xxxxx Telerate Service (or such other page or service as may replace
that page or service for the purpose of displaying rates comparable to said
US Treasury Securities). If the publishing of the foregoing Statistical
Release is ever discontinued, the applicable Reference Rate shall be based on
the publication by the Board of Governors of the United States Federal
Reserve System in replacement thereof, or if none, the publication which in
the Holder's discretion most nearly corresponds.
CALCULATION OF PREPAYMENT FEE
1. If the Initial Reference Rate is less than or equal to the Final
Reference Rate, there is no prepayment fee.
2. If the Initial Reference Rate is greater than the Final Reference
Rate, the prepayment fee shall be equal to the difference between the Initial
Reference Rate and the Final Reference Rate (expressed as a decimal),
multiplied by the appropriate factor from the Prepayment Fee Factor Schedule,
multiplied by the principal amount of the Loan being prepaid.
EXAMPLE OF PREPAYMENT FEE CALCULATION
An amortizing loan with remaining principal of $250,000 is fully prepaid
with twenty-four (24) months remaining until maturity. An Initial Reference
Rate of 9.000% was assigned to the loan at the time the loan was closed. The
Final Reference Rate (as determined by the current 24-month US Treasury Rate
on Page 119 of Telerate) is 7.500%. Rates therefore have dropped 1.500% since
the loan was closed and a prepayment fee applies. A prepayment fee factor of
1.3 is determined from Table 1 below and the prepayment fee is computed as
follows:
Prepayment Fee = (0.09 - 0.075) x (1.3) x ($250,000) = $4,875.00
1
FEE FACTOR SCHEDULES
TABLE 1 - FULLY AMORTIZING LOANS
Proportion of Remaining
Principal Amount
Being Prepaid
Months Remaining to Maturity(1)
0 3 6 9 12 24 36 48 60 84 120 240 360
---------------------------------------------------------------------------
90- 100% 0 .21 .36 .52 .67 1.3 1.9 2.5 3.1 4.3 5.9 10.3 13.1
60- 89% 0 .24 .44 .63 .83 1.6 2.4 3.1 3.9 5.4 7.5 13.2 17.0
30- 59% 0 .28 .53 .78 1.02 2.0 3.0 4.0 5.0 7.0 9.9 18.5 24.4
0- 29% 0 .31 .63 .92 1.22 2.4 3.7 5.0 6.3 9.0 13.4 28.3 41.8
TABLE 2 - PARTIALLY AMORTIZING LOANS
Proportion of Remaining
Principal Amount
Being Prepaid
Months Remaining to Maturity(1)
0 3 6 9 12 24 36 48 60 84 120 240 360
---------------------------------------------------------------------------
90- 100% 0 .26 .49 .71 .94 1.8 2.7 3.4 4.2 5.6 7.4 11.6 14.0
60- 89% 0 .30 .59 .86 1.15 2.2 3.3 4.3 5.3 7.1 9.4 15.0 18.1
30- 59% 0 .31 .63 .95 1.27 2.6 3.9 5.3 6.6 9.1 12.6 21.2 26.2
0- 29% 0 .31 .63 .95 1.27 2.6 4.0 5.4 7.0 10.2 15.7 33.4 46.0
(1) If the remaining fixed rate period is between any two time periods
shown in the above schedules, interpolate between the corresponding factors
to the closest month.
The Holder of this Note is not required to actually reinvest the
prepaid principal in any U.S. Government Treasury Securities, or otherwise
prove its actual losses, as a condition to receiving a prepayment fee as
calculated above. Maker agrees this prepayment fee is the bargained-for
consideration to the Holder for permitting prepayment and the above is not a
liquidated damages provision. This prepayment fee provision is to be
interpreted in a manner that would make it enforceable to the fullest extent
permitted by law, with any portion of the fee that is unenforceable being
stricken or otherwise changed to cause the fee, as revised, to be enforced.
2
1 SEAFIRST BANK
PROMISSORY NOTE
Principal Loan Date Maturity Loan No. Call Collateral Account Officer Initials
$1,850,000.00 03-01-97 18/59 AFS 5607
References in the shaded area are for Lender's use only and do not limit the
applicability of this document to any particular loan or item.
Borrower: THE COEUR D'ALENES COMPANY AND UNION
IRON WORKS, INC. OF SPOKANE, WASHINGTON
XX XXX 0000
XXXXXXX, XX 00000
Lender: BANK OF AMERICA NW NA DOING BUSINESS AS
SEAFIRST BANK
EASTERN DIVISION TEAM #1
C/O CLSC-E (DOC'S)
XX XXX 0000 (XXX-0)
XXXXXXX XX 00000-0000
Principal Amount: $1,850,000.00 0.325% Over the Index Date of Note: March 26, 1996
PROMISE TO PAY. THE COEUR D'ALENES COMPANY AND UNION IRON WORKS, INC. OF
SPOKANE, WASHINGTON ("Borrower") promises to pay to BANK OF AMERICA NW N.A.
DOING BUSINESS AS SEAFIRST BANK ("Lender"), or order, In lawful money of the
United Sates of America, the principal amount of One Million Eight Hundred
Fifty Thousand & 00/100 Dollars ($1,850,000.00) or so much as may be
outstanding, together with Interest on the unpaid outstanding principal
balance untill paid in full.
PAYMENT. Borrower will pay this loan In one payment of all outstanding
principal plus all accrued unpaid Interest on March 1, 1997. In addition,
Borrower will pay regular monthly payments of accrued unpaid Interest
beginning April 1, 1996, and all subsequent Interest payments are due on the
same day of each month after that Interest on this Note is computed on a
365/360 simple interest basis; that is, by applying the ratio of the annual
interest rate over a year of 360 days, multiplied by the outstanding
principal balance, multiplied by the actual number of days the principal
balance is outstanding. Borrower will pay Lender at Lender's address shown
above or at such other place as Lender may designate in writing. Unless
otherwise agreed or required by applicable law, payments will be applied
first to accrued unpaid interest, then to principal, and any remaining
amount to any unpaid collection costs and late charges.
AUTOMATIC PAYMENTS. Borrower hereby authorizes Lender to automatically deduct
from Borrower's checking/savings account number 00000000, or such other
Seafirst account as may be authorized in the future, the loan payment
according to the amount and terms of this Note. If the funds in the account
are insufficient to cover any payment, Lender shall not be obligated to
advance funds to cover the payment. At any time and for any reasons Borrower
or Lender may voluntarily terminate Automatic Payments. Our business days
are Monday through Friday. Payments that come due on a Saturday, Sunday or
legal bank holiday, will be deducted on the following business day.
VARIABLE INTEREST RATE. The Interest rate on This Note Is subject to change
from time to time based on changes In an Index which Is the Lender's publicly
announced prime rate (the "Index"). The interest rate change will not occur
more often than each day the prime rate changes. Lender will tell Borrower the
current Index rate upon Borrowers request. Borrower understands that Lender
may make loans based on other rates as well. The interest rate change will
not occur more often than each day. The Interest rate to be applied to the
unpaid principal balance of this Note will be at a rate of 0.325 percentage
points over the Index. NOTICE: Under no circumstances will the interest rate
on this Note be more than the maximum rate allowed by applicable law.
PREPAYMENT. Borrower may pay without penalty all or a portion of the amount
owed earlier than it is due. Early payments will not, unless agreed to by
Lender in writing, relieve Borrower of Borrower's obligation to continue to
make payments under the payment schedule. Rather, they will reduce the
principal balance due and may result in Borrower's making fewer payments.
LATE CHARGE. If a payment is 10 days or more late, Borrower will be charged
5.000% of the regularly scheduled payment or $20.00 whichever is greater.
DEFAULT. Borrower will be in default if any of the following happens: (a)
Borrower fails to make any payment when due. (b) Borrower breaks any promise
Borrower has made to Lender, or Borrower fails to comply with or to perform
when due any other term, obligation, covenant, or condition contained in this
Note or any agreement related to this Note, or in any other agreement or loan
Borrower has with Lender. (c) Any representation or statement made or
furnished to Lender by Borrower or on Borrower's behalf is false or
misleading in any material respect either now or at the time made or
furnished. (d) Borrower becomes insolvent, a receiver is appointed for any
part of Borrowers property, Borrower makes an assignment for the benefit of
creditors, or any proceeding is commenced either by Borrower or against
Borrower under any bankruptcy or insolvency laws. (e) Any creditor tries to
take any of Borrower's property on or in which Lender has a lien or security
interest. This includes a garnishment of any of Borrower's accounts with
Lender. (f) Any of the events described in this default section occurs with
respect to any guarantor of this Note. (g) A material adverse change occurs
in Borrower's financial condition, or Lender believes the prospect of payment
or performance of the Indebtedness is impaired. (h) Lender in good xxxxx
xxxxx itself insecure.
LENDER'S RIGHTS. Upon default, Lender may declare the entire unpaid principal
balance on this Note and all accrued unpaid interest immediately due,
without notice, and then Borrower will pay that amount. Upon default,
including failure to pay upon final maturity, Lender, at its option, may
also, if permitted under applicable law, do one or both of the following: (a)
increase the variable interest rate on this Note to 2.325 percentage points
over the Index, and (b) add any unpaid accrued interest to principal and
such sum will bear interest therefrom untill paid at the rate provided in this
Note (including any increased rate). The interest rate will not exceed the
maximum rate permitted by applicable law. Lender may hire or pay someone
else to help collect this Note if Borrower does not pay. Borrower also will
pay Lender that amount. This includes, subject to any limits under applicable
law Lender's attorneys' fees and Lender's legal expenses whether or not there
is a lawsuit, including attorneys' fees and legal expenses for bankruptcy
proceedings (including efforts to modify or vacate any automatic stay or
injunction), appeals, and any anticipated postjudgment collection services.
If not prohibited by applicable law, Borrower also will pay any court costs,
in addition to all other sums provided by law. This Note has been delivered
to Lender and accepted by Lender In the State of Washington. If there is a
lawsuit, Borrower agrees upon Lender's request to submit to the jurisdiction
of the courts situated In King County, the State of Washington This Note
shall be governed by and construed in accordance with the laws of the State
of Washington.
LINE OF CREDIT. This Note evidences a revolving line of credit. Advances
under this Note, as well as directions for payment from Borrowers accounts,
may be requested orally or in writing by Borrower or by an authorized
person. Lender may, but need not, require that all oral requests be
confirmed in writing. The following party or parties are authorized to
request advances under the line of credit untill Lender receives from Borrower
at Lender's address shown above written notice of revocation of their
authority: XXXXXX X X XXXXXXX and XXXXXXX XXXXXXXXX. Borrower agrees to be
liable for all sums either: (a) advanced in accordance with the instructions
of an authorized person or (b) credited to any of Borrowers accounts with
Lender. The unpaid principal balance owing on this Note at any time may be
evidenced by endorsements on this Note or by Lender's internal records,
including daily computer print-outs. Lender will have no obligation to
advance funds under this Note if: (a) Borrower or any guarantor is in default
under the terms of this Note or any agreement that Borrower or any guarantor
has with Lender, including any agreement made in connection with the signing
of this Note; (b) Borrower or any guarantor ceases doing business or is
insolvent; (c) any guarantor seeks, claims or otherwise
PROMISSORY NOTE Page 2
(Continued)
attempts to limit modify or revoke such guarantor's guarantee of this Note or
any other loan with Lender; (d) Borrower has applied funds provided pursuant
to this Note for purposes other than those authorized by Lender; or (e)
Lender in good xxxxx xxxxx itself insecure under this Note or any other
agreement between Lender and Borrower.
STATUTE OF FRAUDS PROVISION. ORAL AGREEMENTS OR ORAL COMMITMENTS TO LOAN
MONEY, EXTEND CREDIT OR TO FORBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT
ENFORCEABLE UNDER WASHINGTON LAW.
GENERAL PROVISIONS. Lender may delay or forgo enforcing any of its rights or
remedies under this Note without losing them. Borrower and any other person
who signs, guarantees or endorses this Note, to the extent allowed by law,
waive presentment, demand for payment, protest and notice of dishonor. Upon
any change in the terms of this Note, and unless otherwise expressly stated
in writing, no party who signs this Note, whether as maker, guarantor,
accommodation maker or endorser, shall be released from liability. All such
parties agree that Lender may renew, extend (repeatedly and for any length
of time) or modify this loan, with the consent of Borrower, or release any
party or guarantor; or impair, fail to realize upon or perfect Lender's
security interest in the collateral; and take any other action deemed
necessary by Lender without the consent of or notice to anyone.
PRIOR TO SIGNING THIS NOTE, BORROWER READ AND UNDERSTOOD ALL THE PROVISIONS
OF THIS NOTE, INCLUDING THE VARIABLE INTEREST RATE PROVISIONS. BORROWER
AGREES TO THE TERMS OF THE NOTE AND ACKNOWLEDGES RECEIPT OF A COMPLETED COPY
OF THE NOTE.
BORROWER:
THE COEUR D'ALENES COMPANY AND UNION IRON WORKS, INC. OF SPOKANE, WASHINGTON
By: /S/ Xxxxxxx Xxxxxxxxx By: /S/ Xxxxxxx Xxxxxxxxx
.......................... ...........................
THE COEUR D'ALENES COMPANY UNION IRON WORKS, INC. OF
SPOKANE, WASHINGTON
[LOGO]
PROMISSORY NOTE
-----------------------------------------------------------------------------------------
PRINCIPAL LOAN DATE MATURITY LOAN NO CALL COLLATERAL ACCOUNT OFFICER INITIALS
$250,000.00 09-30-2003 AFS 1701484046 85607
-----------------------------------------------------------------------------------------
References in the shaded area are for Lender's use only and do not limit the
applicability of this document to any particular loan or item.
-----------------------------------------------------------------------------------------
Borrower: THE COEUR D'ALENES COMPANY Lender: BANK OF AMERICA NW NA D/B/A
AND UNION IRON WORKS, INC OF SEAFIRST BANK
SPOKANE, WASHINGTON EASTERN DIVISION TEAM #1
XX XXX 0000 X/X XXXX-X (XXX'X)
XXXXXXX XXXXXXXXXX 00000 X.X. XXX 0000 (XXX-0)
XXXXXXX, XXXXXXXXXX 00000-0000
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
Principal Amount: $250,000.00 0.500% Over the Index Date of Note:
September 17, 1996
PROMISE TO PAY. THE COEUR D'ALENES COMPANY AND UNION IRON WORKS, INC OF SPOKANE,
WASHINGTON ("Borrower") promises to pay to BANK OF AMERICA NW NA D/B/A SEAFIRST
BANK ("Lender"), or order, in lawful money of the United States of America, the
principal amount of Two Hundred Fifty Thousand & 00/100 Dollars (S250,000.00),
together with interest on the unpaid principal balance until paid in full.
PAYMENT. Subject to any payment changes resulting from changes in the Index,
Borrower will pay this loan In 84 payments of S4,018.38 each payment. Borrower's
first payment is due October 30, 1996, and all subsequent payments are due on
the same day of each month after that. Borrower's final payment will be due on
September 30, 2003, and will be for all principal and all accrued Interest not
yet paid. Payments Include principal and Interest. Interest on this Note is
computed on a 365/360 simple interest basis, that is, by applying the ratio of
the annual interest rate over a year of 360 days, multiplied by the outstanding
principal balance, multiplied by the actual number of days the principal balance
is outstanding. Borrower will pay Lender at Lender's address shown above or at
such other place as Lender may designate in writing. Unless otherwise agreed or
required by applicable law, payments will be applied first to accrued unpaid
interest, then to principal, and any remaining amount to any unpaid collection
costs and late charges.
AUTOMATIC PAYMENTS. Borrower hereby authorizes Lender to automatically deduct
from Borrower's checking/savings account number 00000000, or such other Seafirst
account as may be authorized in the future, the loan payment according to the
amount and terms of this Note. If the funds in the account are insufficient to
cover any payment, Lender shall not be obligated to advance funds to cover the
payment. At any time and for any reasons, Borrower or Lender may voluntarily
terminate Automatic Payments. Our business days are Monday through Friday.
Payments that come due on a Saturday, Sunday or legal bank holiday, will be
deducted on the following business day.
VARIABLE INTEREST RATE. The interest rate on this Note is subject to change from
time to time based on changes. In an Index which is the Lender's publicly
announced prime rate (the "Index"). The interest rate change will not occur more
often than each day the prime rate changes Lender will tell Borrower the current
Index rate upon Borrower's request. Borrower understands that Lender may make
loans based on other rates as well. The interest rate change will not occur more
often than each day. The Interest rate to be applied to the unpaid principal
balance of this Note will be at a rate of 0.500 percentage points over the
Index. NOTICE: Under no circumstances will the interest rate on this Note be
more than the maximum rate allowed by applicable law.
PREPAYMENT. Borrower may pay without penalty all or a portion of the amount owed
earlier than it is due. Early payments will not, unless agreed to by Lender in
writing, relieve Borrower of Borrower's obligation to continue to make payments
under the payment schedule. Rather, they will reduce the principal balance due
and may result in Borrower's making fewer payments.
LATE CHARGE. If a payment is 10 days or more late, Borrower will be charged
5.000% of the regularly scheduled payment or $20.00, whichever is greater.
DEFAULT. Borrower will be in default if any of the following happens: (a)
Borrower fails to make any payment when due, (b) Borrower breaks any promise
Borrower has made to Lender, or Borrower fails to comply with or to perform when
due any other term, obligation, covenant, or condition contained in this Note or
any agreement related to this Note, or in any other agreement or loan Borrower
has with Lender, (c) Any representation or statement made or furnished to Lender
by Borrower or on Borrower's behalf is false or misleading in any material
respect either now or at the time made or furnished, (d) Borrower becomes
insolvent, a receiver is appointed for any part of Borrower's property, Borrower
makes an assignment for the benefit of creditors, or any proceeding is commenced
either by Borrower or against Borrower under any bankruptcy or insolvency laws,
(e) Any creditor tries to take any of Borrower's property on or in which Lender
has a lien or security interest. This includes a garnishment of any of
Borrower's accounts with Lender, (f) Any of the events described in this
default section occurs with respect to any guarantor of this Note, (g) A
material adverse change occurs in Borrower's financial condition, or Lender
believes the prospect of payment or performance of the Indebtedness is impaired,
(h) Lender in good xxxxx xxxxx itself insecure.
LENDER'S RIGHTS. Upon default, Lender may declare the entire unpaid principal
balance on this Note and all accrued unpaid interest immediately due, without
notice, and then Borrower will pay that amount. Upon default, including failure
to pay upon final maturity, Lender, at its option, may also, if permitted under
applicable law, do one or both of the following: (a) increase the variable
interest rate on this Note to 2.500 percentage points over the Index, and (b)
add any unpaid accrued interest to principal and such sum will bear interest
therefrom until paid at the rate provided in this Note (including any increased
rate). The interest rate will not exceed the maximum rate permitted by
applicable law. Lender may hire or pay someone else to help collect this Note if
Borrower does not pay. Borrower also will pay Lender that amount. This includes,
subject to any limits under applicable law, Lender's attorneys' fees and
Lender's legal expenses whether or not there is a lawsuit, including attorneys'
fees and legal expenses for bankruptcy proceedings (including efforts to modify
or vacate any automatic stay or injunction), appeals, and any anticipated post-
judgment collection services. If not prohibited by applicable law, Borrower also
will pay any court costs, in addition to all other sums provided by law. This
Note has been delivered to Lender and accepted by Lender in the State of
Washington. If there is a lawsuit, Borrower agrees upon Lender's request to
submit to the jurisdiction of the courts situated in King County, the State of
Washington This Note shall be governed by and construed in accordance with the
laws of the State of Washington.
STATUTE OF FRAUDS PROVISION. ORAL AGREEMENTS OR ORAL COMMITMENTS TO LOAN MONEY,
EXTEND CREDIT OR TO FORBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT
ENFORCEABLE UNDER WASHINGTON LAW.
[LOGO]
DEED OF TRUST, SECURITY AGREEMENT
AND FIXTURE FILING WITH ASSIGNMENT
OF LEASES AND RENTS
THIS DEED OF TRUST, SECURITY AGREEMENT AND FIXTURE FILING WITH ASSIGNMENT
OF LEASES AND RENTS ("Deed of Trust") is made December 20, 1995 by THE COEUR
D'ALENES COMPANY, an Idaho corporation, as "Grantor", whose address is East
0000 Xxxxxxxx Xxxxxx, Xxxxxxx, XX 00000; to RAINIER CREDIT COMPANY, as
"Trustee", whose address is X.X. Xxx 00000, XXX-X0, Xxxxxxx, XX 00000-0000;
for the benefit of SEATTLE-FIRST NATIONAL BANK, a national banking
association, as "Beneficiary", whose address is 000 Xxxxx Xxxxxx, 00xx Xxxxx,
Xxxxxxx, XX 00000, Attention: Real Estate Loan Administration.
ARTICLE I
1. GRANTING CLAUSE. Grantor irrevocably grants, bargains, sells and
conveys to Trustee and its successors and assigns in trust, with power of
sale and with right of entry and possession as provided herein, all Grantor's
estate, right, title, interest, claim and demand, now owned or hereafter
acquired, in and to the following (the "Property"):
(a) The real property in Spokane County, Washington, described in
SCHEDULE A attached and any and all improvements now or hereafter located
thereon (the "Real Property").
(b) All land lying in streets and roads adjoining the Real Property,
and all access rights and easements pertaining to the Real Property.
(c) All the lands, tenements, privileges, reversions, remainders,
irrigation and water rights and stock, oil and gas rights, royalties,
minerals and mineral rights, all development rights and credits, air rights,
hereditaments and appurtenances belonging or in any way pertaining to the
Real l'roperty.
(d) All buildings, structures, improvements, fixtures, equipment and
machinery and property now or hereafter attached to or used in connection
with the use, occupancy or operation of the Real Property including, but not
limited to, heating and incinerating apparatus and equipment, boilers,
engines, motors, generating equipment, telephone and other communication
systems, piping and plumbing fixtures, ranges, cooking apparatus and
mechanical kitchen equipment, refrigerators, cooling, ventilating, sprinkling
and vacuum cleaning systems, fire extinguishing apparatus, gas and electric
fixtures, irrigation equipment, carpeting, underpadding, elevators,
escalators, partitions, mantles, built-in mirrors, window shades, blinds,
screens, storm sash, awnings, furnishings of public spaces, halls and
lobbies, and shrubbery and plants, but excluding them from all personal
property, inventory and equipment used in the operation of Grantor's
fabrication and distribution business on the Property including, without
limitation, all metal processing (i.e., press brake, shears), fabrication
(i.e., welders), and distribution (i.e., saws, storage racks) equipment. All
property mentioned in this subsection (d) shall be deemed part of the realty
and not severable wholly or in part without material injury to the Real
Property.
(e) All rents, issues and profits of the Real Property, all existing
and future leases of the Real Property (including extensions, renewals and
subleases), all agreements for use and occupancy of the Real Property (all
such leases and agreements whether written or oral, are hereafter referred to
as the "Leases"), and all guaranties of lessees' performance under the
Leases, together with
-1-
the immediate and continuing right to collect and receive all of the rents,
income, receipts, revenues, issues, profits and other income of any nature
now or hereafter due (including any income of any nature coming due during
any redemption period) under the Leases or from or arising out of the Real
Property including minimum rents, additional rents, percentage rents, parking
or common area maintenance contributions, tax and insurance contributions,
deficiency rents, liquidated damages following default in any Lease, all
proceeds payable under any policy of insurance covering loss of rents
resulting from untenantability caused by destruction or damage to the Real
Property, all proceeds payable as a result of exercise of an option to
purchase the Real Property, all proceeds derived from the termination or
rejection of any Lease in a bankruptcy or other insolvency proceeding, all
security deposits or other deposits for the performance of any lessee's
obligations under the Leases, and all proceeds from any rights and claims of
any kind which Grantor may have against any lessee under the Leases or any
occupants of the Real Property (all of the above are hereafter collectively
referred to as the "Rents"). This subsection (e) is subject to the right,
power and authority given to the Beneficiary in the Loan Documents (as
defined herein) to collect and apply the Rents.
(f) All of Grantor's rights to further encumber said Real Property
for debt and all Grantor's rights to enter into any lease agreement which
would create a tenancy that is or may become subordinate in any respect to
any mortgage or deed of trust other than this Deed of Trust, but excluding
the existing deed of trust (and which is subordinate to this Deed of Trust)
securing payment of convertible debentures issued by Grantor.
2. COLLATERAL. The following described estate, property and rights of
Grantor are also included as security for the performance of each covenant
and agreement of Grantor contained herein and the payment of all sums of
money secured hereby:
(a) All furniture, furnishings, appliances, machinery, vehicles,
equipment and all other property of any kind now or hereafter located on the
Property, used or intended to be used on the Property wherever actually
located, or purchased with the proceeds of the Note (as defined herein), but
excluding them from all personal property, inventory and equipment used in
the operation of Grantor's automotive business on the Property including,
without limitation, all metal processing (i.e., press brake, shears),
fabrication (i.e., welders), and distribution (i.e., saws, storage racks)
equipment and all rights of Grantor as lessee of any property described in
this Section 2 and subsection l (d) above.
(b) All compensation, awards, damages, rights of action and proceeds
(including insurance proceeds and any interest on any of the foregoing)
arising out of or relating to a taking or damaging of the Property by reason
of any public or private improvement, condemnation proceeding (including
change of grade), fire, earthquake or other casualty, injury or decrease in
the value of the Property.
(c) All returned premiums or other payments on any insurance
policies pertaining to the Property and any refunds or rebates of taxes or
assessments on the Property.
(d) All rights to the payment of money, accounts receivable,
deferred payments, refunds, cost savings, payments and deposits, whether now
or later to be received from third parties (including all utility deposits),
architectural and engineering plans, specifications and drawings, contract
rights, governmental permits and licenses, and agreements and purchase orders
which pertain to or are incidental to the design or construction of any
improvements on the Property, Grantor's rights under any payment,
performance, or other bond in connection with construction of improvements on
the Property, and all construction materials, supplies, and equipment
delivered to the Property or intended to be used in connection with the
construction of improvements on the Property wherever actually located.
(e) All contracts and agreements pertaining to or affecting the
Property including, but not limited to, management, operating and franchise
agreements, licenses, trade names and trademarks.
-2-
(f) All of Grantor's interest in and to the proceeds of the loan
(the "Loan") evidenced by the Note (defined below), whether disbursed or not,
any account into which Loan proceeds are deposited, and Grantor's own funds
now or later held on deposit as equity funds or for payment of bills relating
to the Property.
(g) All loan commitments or other agreements, now or hereafter in
existence, which will provide Grantor with proceeds to satisfy the Secured
Obligations (defined below) and the right to receive the proceeds due under
such commitments or agreements including refundable deposits and fees.
(h) All books and records pertaining to any and all of the Property
and the other collateral described above, including computer readable memory
and any computer hardware or software necessary to access and process such
memory.
(i) All additions, accessions, replacements, substitutions, proceeds
and products of the Property described in this Section 2 and of any of the
Property which is personal property.
The Property and all of the property and rights described in Sections I and 2
above are referred to collectively in this Deed of Trust as the "Collateral".
3. SECURITY AGREEMENT. If any of the Collateral is determined to be
personal property, Grantor as Debtor hereby grants to Beneficiary as Secured
Party a security interest in all such personal property to secure payment and
performance of the Secured Obligations. This Deed of Trust constitutes a
security agreement between Grantor and Beneficiary pursuant to the Uniform
Commercial Code as adopted in the State of Washington, as now or hereafter
amended, with respect to the Collateral, and any and all property affecting
or related to the use and enjoyment of the Property, now or hereafter
described in any Uniform Commercial Code Financing Statement naming Grantor
as Debtor and Beneficiary as Secured Party. The remedies of Beneficiary for
any violation of the covenants, terms and conditions of this Deed of Trust or
any other Loan Document (defined below) shall include all remedies available
to secured parties under the Uniform Commercial Code. Grantor agrees the
filing of a financing statement in the records normally having to do with
personal property shall not be construed as in anywise derogating from or
impairing the intention of Grantor and Beneficiary that everything used in
connection with the production of income from the Property that is the
subject of this Deed of Trust and/or adapted for use therein and/or which is
described or reflected in this Deed of Trust is, and at all times and for all
purposes and in all proceedings both legal or equitable shall be, regarded as
part of the real estate irrespective of whether (i) any such item is
physically attached to the improvements, (ii) serial numbers are used for the
better identification of certain equipment items capable of being thus
identified in any list filed with the Beneficiary, or (iii) any such item is
referred to or reflected in any such financing statement so filed at any time.
4. FINANCING STATEMENT. This Deed of Trust shall also constitute a
financing statement filed for record in the real estate records as a fixture
filing pursuant to the Uniform Commercial Code. This Deed of Trust may be
given to secure an obligation incurred for the construction of improvements
on the Property, including the acquisition of the Property, or to secure an
obligation incurred to refinance an obligation incurred for the construction
of improvements on the Property, including the acquisition of the Property.
5. OBLIGATIONS SECURED. The following obligations ("Secured Obligations")
are secured by this Deed of Trust:
(a) Payment of the sum of ONE MILLION SIX HUNDRED EIGHTY-EIGHT
THOUSAND AND NO/100 DOLLARS ($1,688,000.00) with interest thereon according
to the terms of a promissory note of even date herewith, payable to
Beneficiary or order and made by Grantor, including all renewals, amendments,
modifications, extensions and substitutions therefor (the "Note"). THE NOTE
MAY CONTAIN PROVISIONS ALLOWING FOR CHANGES IN THE INTEREST RATE.
(b) Payment of any further sums now or hereafter advanced or loaned
by Beneficiary to Grantor, or any of its successors or assigns, and payment
of every other present and
-3-
future obligation owing by Grantor to Beneficiary of any kind, and all
renewals, modifications, and extensions thereof, including any interest,
fees, costs, service charges, indemnifications and expenses connected with
such obligations, if (i) the promissory note or other written document
evidencing the future advance or loan or other obligation specifically states
that it is secured by this Deed of Trust, or (ii) the advance, including
costs and expenses incurred by Beneficiary, is made pursuant to the Note,
this Deed of Trust or any other documents executed by Grantor evidencing,
securing, or relating to the Loan, and/or the Collateral, whether executed
prior to, contemporaneously with, or subsequent to this Deed of Trust (this
Deed of Trust, the Note and all such other documents, including any
construction or other loan agreement, and all renewals, amendments,
modifications or extensions thereof, are hereafter collectively referred to
as the "Loan Documents"), together with interest thereon at the rate set
forth in the Note, unless otherwise specified in the Loan Documents or agreed
in writing.
(c) Performance of each agreement, term and condition set forth or
incorporated by reference in the Loan Documents, as such may be amended.
(d) Performance and payment of the obligations of Grantor (or any
other obliger under the Note) under each and every existing or future "swap
transaction" (i.e., any transactions governed by an ISDA master agreement) to
which Grantor (or the obligor under the Note) and Beneficiary are parties, if
this Deed of Trust is referenced in such transaction as a credit support
document.
Notwithstanding any of the foregoing, the Secured Obligations shall not
include the obligations of Grantor under any Certificate and Indemnity
Agreement Regarding Building Laws and Hazardous Substances now or hereafter
executed by Grantor (or any other person or entity) in connection with the
loan evidenced by the Note.
ARTICLE II
1. ASSIGNMENT OF RENTS AND LEASES. Grantor hereby absolutely and
irrevocably assigns to Beneficiary all Grantor's interest in the Rents and
Leases. The foregoing assignment is subject to the terms and conditions of
any separate assignment of the Leases and/or Rents, whenever executed, in
favor of Beneficiary and covering the Property. Grantor warrants it has made
no prior assignment of the Rents or the Leases and will make no subsequent
assignment (other than to Beneficiary) without the prior written consent of
Beneficiary. At Beneficiary's request, Grantor shall execute and deliver to
Beneficiary a separate assignment of rents containing such terms and
conditions as Beneficiary may reasonably require.
(a) Unless otherwise provided in any separate assignment of the
Leases and/or the Rents, and so long as Grantor is not in default under the
Loan Documents, Grantor may collect the Rents as the Rents become due.
Grantor shall use the Rents to pay normal operating expenses for the Property
and sums due and payments required under the Loan Documents. No Rents shall
be collected for a period subsequent to the current one month rental period
and first or last month's rent. Grantor's right to collect the Rents shall
not constitute Beneficiary's consent to the use of cash collateral in any
bankruptcy proceeding.
(b) If Grantor is in default under this Deed of Trust or any other
Loan Document, without notice to Grantor, Beneficiary or its agents, or a
court appointed receiver, may collect the Rents. In doing so, Beneficiary may
(i) evict lessees for nonpayment of rent, (ii) terminate in any lawful manner
any tenancy or occupancy, (iii) lease the Property in the name of the then
owner on such terms as it may deem best, (iv) institute proceedings against
any lessee for past due rent, and (v) do all other acts and things as
Beneficiary deems necessary or desirable. The Rents received shall be applied
to payment of the costs and expenses of collecting the Rents, including a
reasonable fee to Beneficiary, a receiver or an agent, operating expenses for
the Property and any sums due or payments required under the Loan Documents,
in such order as Beneficiary may determine. Any excess shall be paid to
Grantor, however, Beneficiary may withhold from any excess a reasonable
amount to pay sums anticipated to become due which exceed the anticipated
future Rents. Beneficiary's failure to collect or discontinuing collection at
any time shall not in any manner affect the subsequent enforcement by
Beneficiary of its rights to collect the Rents. The collection of the
-4-
Rents by or for Beneficiary shall not cure or waive any default under the
Loan Documents. Any Rents paid to Beneficiary or a receiver shall be credited
against the amount due from the lessees under the Leases. In the event any
lessee under a Lease becomes the subject of any proceeding under the
Bankruptcy Code or any other federal, state or local statute which provides
for the possible termination or rejection of any Lease assigned hereby,
Grantor covenants and agrees that in the event any of the Leases are so
rejected, no damages settlement shall be made without the prior written
consent of Beneficiary; any check in payment of damages for rejection or
termination of any such Lease will be made payable both to the Grantor and
Beneficiary; and Grantor hereby assigns any such payment to Beneficiary and
further covenants and agrees that upon request of Beneficiary, it will duly
endorse to the order of Beneficiary any such check, the proceeds of which
will be applied to any portion of the indebtedness secured hereunder in such
manner as Beneficiary may elect.
(c) Regardless of whether or not Beneficiary, in person or by agent,
takes actual possession of the Property or any part thereof, Beneficiary is
not and shall not be deemed to be: (i) "a mortgagee in possession" for any
purpose; (ii) responsible for performing any of the obligations of the lessor
under any Lease; (iii) responsible for any waste committed by lessees or any
other parties, any dangerous or defective condition of the Property, or any
negligence in the management, upkeep, repair or control of the Property; or
(iv) liable in any manner for the Property or the use, occupancy, enjoyment
or operation of all or any part of it. In exercising its rights under this
Section I Beneficiary shall be liable only for the proper application of and
accounting for the Rents collected by Beneficiary or its agents.
2. LEASES. Grantor shall fully comply with all of the terms, conditions
and provisions of the Leases so that the same shall not become in default and
do all things necessary to preserve the Leases in force. Unless otherwise
agreed in writing by Beneficiary, without Beneficiary's prior written
consent, Grantor will not enter into any Lease (i) on a form of Lease not
previously approved by Beneficiary, (ii) for a term of three (3) years or
more, or (iii) containing an option or right to purchase all or any part of
the Collateral in favor of any lessee. With respect to any Lease of the whole
or any part of the Property involving an initial term of three (3) years or
more, Grantor shall not, without the prior written consent of Beneficiary,
(a) permit the assignment or subletting of all or part ofthe lessee's rights
under the Lease unless the right to assign or sublet is expressly reserved by
the lessee under the Lease, (b) modify or amend the Lease for a lesser rental
or term, or (c) accept surrender of the Lease or terminate the Lease except
in accordance with the terms of the Lease providing for termination in the
event of a default. Any proceeds or damages result from a lessee's default
under any Lease, at Beneficiary's option, shall be paid to Beneficiary and
applied against sums owed under the Loan Documents even though such sums may
not be due and payable. Except for real estate taxes and assessments, without
Beneficiary's prior written consent, Grantor shall not permit any lien to be
created against the Property which may be or may become prior to any Lease.
If the Property is partially condemned or suffers a casualty, Grantor shall
promptly repair and restore the Property in order to comply with the Leases.
ARTICLE III
1. NON-AGRICULTURAL USE. Grantor represents and warrants to Beneficiary
that neither the Property nor any other Collateral is used principally or
primarily for agricultural or farming purposes.
2. PERFORMANCE OF OBLIGATIONS. Grantor shall promptly and timely pay all
sums due pursuant to the Loan Documents, strictly comply with all the terms
and conditions of the Loan Documents, and perform each Secured Obligation in
accordance with its terms.
3. WARRANTY OF TITLE. Grantor warrants that it has good and marketable
title to an indefeasible fee simple estate in the Property (unless Grantor's
present interest in the Property is described in SCHEDULE A as a leasehold
interest, in which case Grantor warrants that it lawfully possesses and holds
a valid leasehold interest in the Property as described in SCHEDULE A), and
good marketable title to the personal property Collateral, subject to no
liens, encumbrances, easements, assessments, security interests, claims or
defects of any kind prior or subordinate to the lien of this Deed of Trust,
except those listed in Beneficiary's title insurance policy or approved by
Beneficiary in writing (the "Exceptions") and real estate taxes and
assessments for the current year. Grantor
-5-
warrants the Exceptions and the real estate taxes and assessments are not
delinquent or in default, and Grantor has the right to convey the Property to
Trustee for the benefit of Beneficiary, and the right to grant a security
interest in the personal property Collateral. Grantor will warrant and defend
title to the Collateral and will defend the validity and priority of the lien
of this Deed of Trust and the security interests granted herein against any
claims or demands.
4. PROHIBITED LIENS.
(a) Subject to Grantor's rights under subsection (b) below, Grantor
shall not permit any governmental or statutory liens (including taxes,
mechanic's or materialmen's liens) to be filed against the Collateral except
for real estate taxes and assessments not yet due and liens permitted by the
Loan Documents or approved by Beneficiary in writing.
(b) Grantor will have the right to contest in good faith by
appropriate legal or administrative proceeding the validity of any prohibited
lien, encumbrance or charge so long as (i) no default exists under the Loan
Documents, (ii) Grantor first deposits with Beneficiary a bond or other
security satisfactory to Beneficiary in the amount reasonably required by
Beneficiary, but not more than the amounts specified in RCW 60.04.161, as now
or hereafter amended, (iii) Grantor immediately commences its contest of such
lien, encumbrance or charge, applies to court for a show cause as provided
for in RCW 60.04.221(9), as now or hereafter amended, and continuously
pursues the contest in good faith and with due diligence; (iv) foreclosure of
the lien, encumbrance or charge is stayed; and (v) Grantor pays any judgment
rendered for the lien claimant or other third party within ten (10) days
after the entry of the judgment. If the contested item is a mechanic's or
materialmen's lien, Grantor will furnish Beneficiary with an endorsement to
its title insurance policy which insures the priority of this Deed of Trust
over the lien being contested. Grantor will discharge or elect to contest and
post an appropriate bond or other security within twenty (20) days of written
demand by Beneficiary.
5. PAYMENT OF TAXES AND OTHER ENCUMBRANCES. Grantor shall pay the real
estate taxes and any assessments or ground rents at least seven (7) days
prior to delinquency unless otherwise provided for in the reserve account
described in Section 15 below. All other encumbrances, charges and liens
affecting the Collateral, including mortgages and deeds of trust, whether
prior to or subordinate to the lien of this Deed of Trust, shall be paid when
due and shall not be in default. On request Grantor shall furnish evidence of
payment of these items.
6. MAINTENANCE--NO WASTE. Grantor shall protect and preserve the
Collateral and maintain it in good condition and repair. Grantor shall do all
acts and take all precautions which, from the character and use of the
Collateral, are reasonable, proper or necessary to so maintain, protect and
preserve the Collateral. Grantor shall not commit or permit any waste of the
Collateral.
7. ALTERATIONS, REMOVAL AND DEMOLITION. Unless otherwise agreed in
writing by Beneficiary, Grantor shall not structurally alter, remove or
demolish any building or improvement on the Property without Beneficiary's
prior written consent. Grantor shall not remove any fixture or other item of
property which is part of the Collateral without Beneficiary's prior written
consent unless the fixture or item of property is replaced by an article of
equal suitability, owned by Grantor free and clear of any lien or security
interest.
8. COMPLETION, REPAIR AND RESTORATION. Grantor shall promptly complete or
repair and restore in good workmanlike manner any building or improvement on
the Property which may be constructed or damaged or destroyed and shall pay
all costs incurred therefor. Prior to commencement of any construction
Grantor shall submit the plans and specifications for Beneficiary's approval
and furnish evidence of sufficient funds to complete the work.
9. COMPLIANCE WITH LAWS. Grantor shall comply with all laws, ordinances,
regulations, covenants, conditions, and restrictions affecting the
Collateral, including, without limitation, all applicable requirements of the
Fair Housing Act of 1968 (as amended) and the Americans With Disabilities Act
of 1990 (as the same may be amended from time to time), and shall not commit
or permit any act upon or concerning the Collateral in violation of any such
laws, ordinances, regulations, covenants, conditions, and restrictions.
Grantor shall defend, indemnify and
-6-
hold Beneficiary harmless from and against all liability threatened against
or suffered by Beneficiary by reason of a breach by Grantor of the foregoing
representations, warranties, covenants and agreements. The foregoing
indemnity shall include the cost of all alterations to the Collateral
(including architectural, engineering, legal and accounting costs), all
fines, fees and penalties, and all legal and other expenses (including
attorneys' fees) incurred in connection with the Property being in violation
of any such laws, ordinances, regulations, covenants, conditions and
restrictions. If Beneficiary or its designee shall become the owner of or
acquire an interest in or rights to the Collateral by foreclosure or deed in
lieu of foreclosure of this Deed of Trust or by other means, the foregoing
indemnification obligation shall survive such foreclosure or deed in lieu of
foreclosure or other acquisition of the Collateral. Notwithstanding the
preceding sentence, Grantor shall have no obligation to defend, indemnify or
hold Beneficiary harmless from any liability arising from or out of the
activities of Beneficiary or its agents with respect to the Collateral on or
after the transfer of the Collateral to Beneficiary pursuant to foreclosure
proceedings or in lieu thereof.
10. IMPAIRMENT OF COLLATERAL. Grantor shall not, without Beneficiary's
prior written consent, change the general nature of the occupancy of the
Property, initiate, acquire or permit any change in any public or private
restrictions (including without limitation a zoning reclassification)
limiting the uses which may be made of the Collateral, or take or permit any
action which would impair the Collateral or Beneficiary's lien or security
interest in the Collateral.
11. INSPECTION OF COLLATERAL. Beneficiary and/or its representative may
inspect the Collateral at reasonable times after reasonable notice.
12. GRANTOR'S DEFENSE O}7 COLLATERAL. Grantor shall appear in and defend
any action or proceeding which may affect the Collateral or the rights or
powers of Beneficiary or Trustee under this Deed of Trust.
13. BENEFICIARY'S RIGHT TO PROTECT COLLATERAL. Beneficiary may commence,
appear in, and defend any action or proceeding which may affect the
Collateral or the rights or powers of Beneficiary or Trustee under this Deed
of Trust. Beneficiary may pay, purchase, contest or compromise any
encumbrance, charge or lien not listed as an Exception which in its judgment
appears to be prior or superior to the lien of this Deed of Trust. If Grantor
fails to make any payment or do any act required under the Loan Documents,
Beneficiary, without any obligation to do so and without releasing Grantor
from any obligations under the Loan Documents, may make the payment or cause
the act to be performed in such manner and to such extent as Beneficiary may
deem necessary to protect the Collateral. Beneficiary is authorized to enter
upon the Property for such purposes. In exercising any ofthese powers
Beneficiary may incur such expenses, in its absolute discretion, it deems
necessary.
14. HAZARDOUS SUBSTANCES.
(a) Grantor represents and warrants to Beneficiary, to the best of
Grantor's knowledge and except as disclosed in Environmental Site Assessment,
Level 1, by Budinger & Associates dated October 2, 1995, a copy of which has
been provided to Beneficiary, no hazardous or toxic waste or substances are
being stored on the Property or any adjacent property nor have any such waste
or substances been stored or used in, on, under, over or about the Property
or any adjacent property prior to or during Grantor's ownership, possession
or control of the Property, other than the use or storage of hazardous or
toxic waste or substances generally used in the ordinary course of operating,
maintaining or developing properties such as the Property, all of which
Grantor covenants have and will be used, stored and disposed of in accordance
with commercially reasonable practices and all applicable federal, state and
local laws, regulations and ordinances. Grantor shall provide written notice
to Beneficiary immediately upon Grantor becoming aware that the Property or
any adjacent property is being or has been contaminated with hazardous or
toxic waste or substances. Grantor will not cause nor permit any activities
on the Property which directly or indirectly could result in the Property or
any other property becoming contaminated with hazardous or toxic waste or
substances. For purposes of this Deed of Trust, the term "hazardous or toxic
waste or substances" means any chemical, substance or material classified or
designated as hazardous, toxic or radioactive, or similar term, and now or
hereafter regulated under any applicable federal, state or
-7-
local statute, regulation, ordinance or requirement, now or hereafter in
effect, pertaining to environmental protection, contamination or cleanup.
(b) Grantor shall comply, at Grantor's expense, with all statutes,
regulations and ordinances which apply to Grantor or the Collateral, and with
all orders, decrees or judgments of governmental authorities or courts having
jurisdiction which Grantor is bound by, relating to the use, collection
storage, treatment, control, removal or cleanup of hazardous or toxic
substances in, on, under, oven or about the Property or in, on, under, over
or about any adjacent property that becomes contaminated with hazardous or
toxic substances as a result of construction, operations or other activities
on, or the contamination of, the Property. Beneficiary may, but is not
obligated to, enter upon the Property to inspect it for compliance and to
take such actions and incur such costs and expenses to effect such compliance
as it deems advisable to protect its interest as Beneficiary; and whether or
not Grantor has actual knowledge of the existence of hazardous or toxic
substances in, on, under, over or about the Property or any adjacent property
as of the date hereof, Grantor slaall reimburse Beneficiary on demand for the
full amount of all costs and expenses incurred by Beneficiary prior to
Beneficiary acquiring title to the Property through foreclosure or deed in
lieu of foreclosure, in connection with such compliance activities.
(c) Grantor's obligations under this Section 14 are unconditional
and shall not be limited by a non-recourse or other limitations of liability
provided for in this Deed of Trust or any other Loan Document.
15. RESERVE ACCOUNT.
(a) Subject to subsection (d) below, if Beneficiary so requires,
Grantor shall pay to Beneficiary monthly, together with and in addition to
any payments due under the Note, a sum, as estimated by Beneficiary, equal to
the ground rents, if any, the real estate taxes and assessments next due on
the Property and the premiums next due on insurance policies required under
the Loan Documents, less all sums already paid therefor, divided by the
number of months to elapse before two (2) months prior to the date when the
ground rents, real estate taxes, assessments and insurance premiums will
become delinquent. The monthly reserve accounts payments and any other
payments due under the Note shall be paid in a single payment and applied by
Beneficiary, at its option, in the following order: (l) ground rents, real
estate taxes, assessments and insurance premiums, (2) expenditures made
pursuant to the Loan Documents and interest thereon, (3) interest on the
Note, and (4) principal due on the Note. Grantor shall promptly deliver to
Beneficiary all bills and notices pertaining to the ground rents, taxes,
assessments and insurance premiums.
(b) The reserve account is solely for the protection of Beneficiary.
Beneficiary shall have no responsibility except to credit properly the sums
actually received by it. No interest will be paid on the funds in the reserve
account and Beneficiary shall have no obligation to deposit the funds in an
interest-bearing account. Upon assignment of this Deed of Trust by
Beneficiary, any funds in the reserve account shall be turned over to the
assignee and any responsibility of Beneficiary with respect thereto shall
terminate. Each transfer of the Property shall automatically transfer to the
grantee all rights of Grantor to any funds in the reserve account.
(c) If the total of the payments to the reserve exceeds the amount
of payments actually made by Beneficiary, plus such amounts as have been
reasonably accumulated in the reserve account toward payments to become due,
such excess may, at Beneficiary's election, be (1) credited by Beneficiary
against sums then due and payable under the Loan Documents, or (2) refunded
to Grantor as its name appears on the records of Beneficiary. If, however,
the reserve account does not have sufficient funds to make the payments when
they become due, Grantor shall pay to Beneficiary the amount necessary to
make up the deficiency within fifteen (15) days after written notice to
Grantor. If this Deed of Trust is foreclosed or if Beneficiary otherwise
acquires the Collateral, the Beneficiary shall, at the time of commencement
of the proceedings or at the time the Collateral is otherwise acquired, apply
the remaining funds in the reserve account, less such sums as will become due
during the pendency of the proceedings, against the sums due under the Loan
Documents and/or to make payments required under the Loan Documents.
-8-
(d) Unless required by the terms of Beneficiary's loan commitment or
any other Loan Document, Grantor shall not be required to pay monthly reserve
account payments so long as there has been no more than four (4) late
payments due under the Note throughout the term of the Loan and there is no
other default under the Loan and so long as Grantor remains in ownership of
the Collateral, provided receipted bills evidencing the payment of all taxes
and/or assessments and insurance premiums are exhibited to Beneficiary within
fifteen (15) days after Beneficiary's reguest therefor. Upon any change in
any of these conditions, Beneficiary may, at its option then or thereafter
exercised, require the payment of reserves pursuant to this Section 15.
16. REPAYMENT OF BENEFICIARY'S EXPENDITURES. Grantor shall pay within ten
( 10) days after written notice from Beneficiary all sums expended by
Beneficiary and all costs and expenses incurred by Beneficiary in taking any
actions pursuant to the Loan Documents including, attorneys' fees,
accountants' fees, appraisal and inspection fees, and the costs for title
reports. If any laws or regulations are passed subsequent to the date of this
Deed of Trust which require Beneficiary to incur out-of-pocket expenses in
order to maintain, modify, extend or foreclose this Deed of Trust, revise the
terms of the Loan or consent to an Accelerating Transfer (as defined below),
Grantor shall reimburse Beneficiary for such expenses within fifteen (15)
days after written notice from Beneficiary. Expenditures by Beneficiary shall
bear interest from the date of such advance or expenditure at the default
interest rate in the Note, shall constitute advances made under this Deed of
Trust and shall be secured by and have the same priority as the lien of this
Deed of Trust. If Grantor fails to pay any such expenditures, costs and
expenses and interest thereon, Beneficiary may, at its option, without
foreclosing the lien of this Deed of Trust, commence an independent action
against Grantor for the recovery of the expenditures and/or advance any
undisbursed Loan proceeds to pay the expenditures.
17. ACCELERATING TRANSFERS.
(a) "Accelerating Transfer" means any sale, contract to sell,
conveyance, encumbrance, transfer of full possessory rights, or other
transfer of all or any material part of the Collateral or any interest in it,
whether voluntary, involuntary, by operation of law or otherwise and whether
or not for record or for consideration. If Grantor is the majority owner of a
business, either through ownership of shares of a corporation or interest in
a partnership, limited liability company or other entity, which occupies
seventy-five percent (75%) or more of the improvements on the Property,
"Accelerating Transfer" also means any sale, contract to sell, or other
transfer of the busincss or substantial assets of the business or the failure
of the business to continue to occupy the Property .
(b) Grantor acknowledges Beneficiary is taking actions in reliance
on the expertise, skill, experience and reliability of Grantor, and the
obligations secured hereby include material elements similar in nature to a
personal service contract or ownership interest. In consideration of
Beneficiary's reliance, Grantor agrees that Grantor shall not make any
Accelerating Transfer without Beneficiary's prior written consent, which
Beneficiary may withhold in its sole discretion. If Beneficiary consents, it
may charge the Grantor a fee as consideration for such consent and condition
its consent on such changes to the terms and conditions of the Note and other
Loan Documents as Beneficiary may require, including without limitation
increasing the interest rate on the Note. Grantor shall pay Beneficiary's
actual costs incurred in making its decision to consent to an Accelerating
Transfer, including but not limited to the cost of credit reports, an updated
appraisal of the Property, an updated environmental assessment and
documentation. If any Accelerating Transfer occurs without Beneficiary's
prior written consent, Beneficiary in its sole discretion may declare an
immediate default and all sums secured by this Deed of Trust to be
immediately due and payable, and Beneficiary may invoke any rights and
remedies provided herein. This provision shall apply to each and every
Accelerating Transfer regardless of whether or not Beneficiary has consented
or waived its rights, whether by action or nonaction, in connection with any
previous Accelerating Transfer(s).
(c) If all or any part of this Section 17 relevant to a particular
Accelerating Transfer is unenforceable according to the law in effect at the
time of the Accelerating Transfer, then Grantor shall reimburse Beneficiary
for its actual costs incurred in processing the Accelerating Transfer on its
records, including but not limited to the cost of modifications of Loan
Documents, an appraisal, and obtaining relevant credit and financial
information.
-9-
18. RELEASE OF PARTIES OR COLLATERAL. Without affecting the obligations
of any party under the Loan Documents and without affecting the lien of this
Deed of Trust and Beneficiary's security interest in the Collateral,
Beneficiary and/or Trustee may, without notice (a) release all or any
Grantor and/or any other party now or hereafter liable for any of the
Secured Obligations (including guarantors), (b) release all or any part of
the Collateral, (c) subordinate the lien of this Deed of Trust or
Beneficiary's security interest in the Collateral, (d) take and/or release
any other security for or guarantees of the Secured Obligations, (e) grant
an extension of time for performance of the Secured Obligations, (f) modify,
waive, forbear, delay or fail to enforce any of the Secured Obligations, (g)
sell or otherwise realize on any other security or guaranty prior to,
contemporaneously with or subsequent to a sale of all or any part of the
Collateral, (h) make advances pursuant to the Loan Documents including
advances in excess of the Note amount, (i) consent to the making of any map
or plat of the Property, and (j) join in the grant of any easement on the
Property. Any subordinate lienholder shall be subject to all such releases,
extensions or modifications without notice to or consent from the
subordinate lienholder. Grantor shall pay any Trustee's, attorneys', title
insurance, recording, inspection or other fees or expenses incurred in
connection with release of Collateral, the making of a map, plat or the
grant of an easement.
ARTICLE IV
1. INSURANCE.
(a) Grantor shall maintain such insurance on the Collateral as may
be required from time to time by Beneficiary, with premiums prepaid,
providing replacement cost coverage and insuring against loss by fire and
such other risks covered by extended coverage insurance, and such other
perils and risks as Beneficiary may require from time to time, including
earthquake, loss of rents and business interruption. Grantor also shall
maintain comprehensive general public liability insurance and if the
Property is located in a designated flood hazard area, flood insurance. All
insurance shall be with companies satisfactory to Beneficiary and in such
amounts and with such coverages as Beneficiary may require from time to time,
with lender's loss payable clauses in favor of and in form satisfactory to
Beneficiary. At least thirty (30) days prior to the expiration of the term
of any insurance policy, Grantor shall furnish Beneficiary with written
evidence of renewal or issuance of a satisfactory replacement policy. If
requested Grantor shall deliver copies of all polices to Beneficiary. Each
policy of insurance shall provide Beneficiary with no less than forty-five
(45) days prior written notice of any cancellation, expiration, non-renewal
or modification.
(b) In the event of foreclosure of this Deed of Trust all interest of
Grantor in any insurance policies pertaining to the Collateral and in any
claims against the policies and in any proceeds due under the policies shall
pass to Beneficiary.
(c) If under the ternis of any Lease the lessee is required to
maintain insurance of the type required by the Loan Documents and if the
insurance is maintained for the benefit of both the lessor and Beneficiary,
Beneficiary will accept such policies provided all of the requirements of
Beneficiary and the Loan Documents are met. In the event the lessee fails to
maintain such insurance, Grantor shall promptly obtain such policies as are
required by the Loan Documents.
(d) If Grantor fails to maintain any insurance required of it by
Beneficiary, or fails to pay any premiums with respect to such insurance,
Beneficiary may obtain such replacement insurance as it deems necessary or
desirable, or pay the necessary premium on behalf of Grantor, and any sums
expended by Beneficiary in so doing shall be added to the principal balance
of the Note and bear interest at the default interest rate set forth in the
Note.
2. DAMAGES AND CONDEMNATION AND INSURANCE PROCEEDS.
(a) Grantor hereby absolutely and irrevocably assigns to Beneficiary,
and authorizes the payor to pay to Beneficiary, the following claims, causes of
action, awards, payments and rights to payment: (i) all awards of damages and
all other compensation payable directly or indirectly because of a
condemnation, proposed condemnation or taking for public or private use which
affects all or part of the Collateral or any interest in it; (ii) all other
awards, claims and causes of action, arising out of any warranty affecting all
or any part of the Collateral, or for damage or
-10-
injury to or decrease in value of all or part of the Collateral or any
interest in it; (iii) all proceeds of any insurance policies payable because
of loss sustained to all or part of the Collateral; and (iv) all interest
which may accrue on any of the foregoing.
(b) Grantor shall immediately notify Beneficiary in writing if: (i)
any damage occurs or any injury or loss is sustained in the amount of $25,000
or more to all or part of the Collateral, or any action or proceeding
relating to any such damage, injury or loss is commenced; or (ii) any offer
is made, or any action or proceeding is commenced, which relates to any
actual or proposed condemnation or taking of all or part of the Collateral.
If Beneficiary chooses to do so, it may in its own name appear in or
prosecute any action or proceeding to enforce any cause of action based on
warranty, or for damage, injury or loss to all or part of the Collateral,
and it may make any compromise or settlement ofthe action or proceeding.
Beneficiary, if it so chooses, may participate in any action or proceeding
relating to condemnation or taking of all or part of the Collateral, and may
join Grantor in adjusting any loss covered by insurance.
(c) All proceeds of these assigned claims, other property and rights
which Grantor may receive or be entitled to shall be paid to Beneficiary. In
each instance, Beneficiary shall apply those proceeds first toward
reimbursement of all of Beneficiary's costs and expenses of recovering the
proceeds, including attorneys' fees.
(d) If, in any instance, each and all of the following conditions are
satisfied in Beneficiary's reasonable judgment, Beneficiary shall permit
Grantor to use the balance of the proceeds ("Net Claims Proceeds") to pay
costs of repairing or reconstructing the Collateral in the manner described
below: (i) the plans and specifications, cost breakdown, construction
contract, construction schedule, contractor and payment and performance bond
for the work of repair or reconstruction must all be acceptable to
Beneficiary; (ii) Beneficiary must receive evidence satisfactory to it that
after repair or reconstruction, the Collateral will be at least as valuable as
it was immediately before the damage or condemnation occurred; (iii) the Net
Claims Proceeds must be sufficient in Beneficiary's determination to pay for
the total cost of repair or reconstruction, including all associated
development costs and interest projected to be payable on the Note until the
repair or reconstruction is complete; or Grantor must provide its own funds
in an amount equal to the difference between the Net Claims Proceeds and a
reasonable estimate, made by Grantor and found acceptable by Beneficiary, of
the total cost of repair or reconstruction; (iv) Beneficiary must receive
evidence satisfactory to it that all Leases which it may find acceptable
will continue after the repair or reconstruction is complete; (v)
Beneficiary has received evidence satisfactory to it, that reconstruction
and/or repair can be completed at least three (3) months prior to the date
the Note secured by this Deed of Trust is due and payable; and (vi) no
default under any of the Loan Documents shall have occurred and be continuing.
If the foregoing conditions are met to Beneficiary's satisfaction,
Beneficiary shall hold the Net Claims Proceeds and any funds which Grantor
is required to provide and shall disburse them to Grantor to pay costs of
repair or reconstruction upon presentation of evidence reasonably
satisfactory to Beneficiary that repair or reconstruction has been completed
satisfactorily and lien-free. However, if Beneficiary finds that one or more
of the conditions are not satisfied, it may apply the Net Claims Proceeds to
pay or prepay some or all of the Note.
ARTICLE V
1. DEFAULT-REMEDIES.
(a) Grantor will be in default under this Deed of Trust upon the
occurrence of any one or more of the following events: (i) Any payment is
not made when due under the Note, this Deed of Trust or any other Loan
Document; (ii) There is a default under, a breach of, or failure to perform
any other covenant, agreement or obligation to be performed under this Deed
of Trust or any other Loan Document or under any guaranty of all or any part
of the Secured Obligations; (iii) Any representation or warranty contained
in this Deed of Trust or any other Loan Document, or any financial
information furnished to Beneficiary in connection with the Loan, proves to
be false or misleading in any material respect; (iv) Grantor defaults under
any lease or other contract or agreement relating to the collateral, and
such default is not cured within the applicable cure period, if any; (v)
Grantor, or the maker of the Note if different from Grantor, is in default
with respect to any other loan from Beneficiary to Grantor and/or such other
borrower; (vi) Grantor, any maker of
-11-
the Note if different from Grantor, or any guarantor of the Loan fails to
pay his, her or its debts generally as they become due, or files a petition
or action for relief under any bankruptcy, or Organization or insolvency
laws or makes an assignment for the benefit of creditors, or (vii) an
involuntary petition is filed against Grantor, any maker of the Note if
different from Grantor, or any guarantor of the Loan under any bankruptcy,
reorganization or other insolvency laws, or a custodian, receiver or trustee
is appointed to take, possession, custody or control of the Collateral or
any other properties or assets of Grantor, of any maker of the Note if
different from Grantor, or of any guarantor of the Loan and such petition or
appointment is not set aside, withdrawn or dismissed within thirty (30) days
from the date of filing or appointment.
(b) In the event of a default Beneficiary may declare the Secured
Obligations, without limitation, the Loan and all other indebtedness
evidenced by the Note or any other Loan Document, immediately due and
payable after notice as set forth in Section 2 below, and/or exercise its
rights and remedies under the Loan Documents and applicable law including,
without limitation, foreclosure of this Deed of Trust judicially as a
mortgage or nonjudicially pursuant to the power of sale. Beneficiary's
exercise of any of its rights and remedies shall not constitute a waiver or
cure of a default. Beneficiary's failure to enforce any of its remedies in
the event of a default shall not constitute a waiver of the default or any
subsequent default of its rights and remedies with respect to such default.
In the event of foreclosure, the cost of the title premium for the trustee's
sale guaranty (or equivalent title policy or report) shall be paid for by
Grantor and shall be added to and be a part of the Secured Obligations. If
this Deed of Trust or any of the other Loan Documents are referred to an
attorney for enforcement or for preservation of Beneficiary's rights or
remedies, and whether or not suit is filed or any proceedings are commenced,
all of Beneficiary's costs and expenses incurred in connection therewith
including, without limitation, Trustee's and attorneys' fees (including
attorneys' fees for any appeal, bankruptcy proceeding or any other
proceeding), accountants' fees, appraisal and internal appraisal review fees,
inspection fees (including inspections for hazardous substances, asbestos
containing materials, and compliance with building and land use codes and
regulations), engineering fees, and expert witness fees and costs of title
reports shall be added to and be a part of the Secured Obligations and shall
be payable on demand.
2. NOTICE AND OPPORTUNITY TO CURE. Notwithstanding any other provision
of this Deed of Trust, Beneficiary shall not accelerate the maturity of one
or more of the Secured Obligations (a) because of a monetary default
(defined below) unless the default is not cured within ten (10) days of the
date on which Beneficiary mails or delivers written notice of the default to
Grantor, or (b) because of a nonmonetary default (defined below) unless the
nonmonetary default is not cured within thirty (30) days of the date on
which Beneficiary mails or delivers written notice of the default to Grantor.
For purposes of this Deed of Trust, the term "monetary default" means a
failure by Grantor to make any payment required of it pursuant to the Note
or any other Loan Document, and the term "nonmonetary default" means a
failure by Grantor or any other person or entity to perform any obligation
contained in the Note or any other Loan Document, other than the obligation
to make payments provided for in the Note or any other Loan Document. If a
nonmonetary default is capable of being cured and the cure cannot reasonably
be completed within the thirty (30) day cure period, the cure period shall
be extended up to ninety (90) days so long as Grantor has commenced action
to cure within the thirty (30) day cure period, and in Beneficiary's opinion,
Grantor is proceeding to cure the default with due diligence. None of the
foregoing shall be construed to obligate Beneficiary to forebear in any
other manner from exercising its remedies and Beneficiary may pursue any
other rights or remedies which Beneficiary may have because of a default.
3. CUMULATIVE REMEDIES. To the fullest extent allowed by law, all of
Beneficiary's and Trustee's rights and remedies specified in the Loan
Documents (including this Deed of Trust) are cumulative, not mutually
exclusive and not in substitution for any rights or remedies available at law
or in equity. Without waiving its rights in the Collateral, Beneficiary may
proceed against Grantor, any other party obligated to pay or perform the
Secured Obligations or against any other security or guaranty for the Secured
Obligations, in such order or manner as Beneficiary may elect. Except where
prohibited by applicable law, the commencement of proceedings to enforce a
particular remedy shall not preclude the commencement of other proceedings of
other proceedings to enforce a different remedy.
-12-
4. ENTRY. After a default, Beneficiary, in person, by agent or by court
appointed receiver, may enter, take possession of, manage and operate all or
any part of the Collateral, and may also do any and all other things in
connection with those actions that Beneficiary may consider necessary and
appropriate to protect the security of this Deed of Trust, including taking
and possessing copies of all of Grantor's or the then owner's books and
records; entering into, enforcing, modifying, or canceling Leases on such
terms and conditions as Beneficiary may consider proper, obtaining and
evicting tenants; fixing or modifying Rents; collecting and receiving any
payment of money owing to Grantor, completing any unfinished construction;
and/or contracting for and making repairs and alterations. Grantor hereby
irrevocably constitutes and appoints Beneficiary as its attorney-in-fact to
perform such acts and execute such documents as Beneficiary in its sole
discretion may consider to be appropriate in connection with taking these
measures. Although the foregoing power of attorney is effective immediately,
Beneficiary shall not exercise the power until the occurrence of a default.
5. APPOINTMENT OF RECEIVER. In the event of a default, Grantor
consents to, and Beneficiary, to the fullest extent permitted by applicable
law, shall be entitled, without notice bond or regard to the adequacy of the
Collateral, to the appointment of a receiver for the Collateral The receiver
shall have, in addition to all the rights and powers customarily given to
and exercised by a receiver, all the rights and powers granted to
Beneficiary by the Loan Documents. The receiver shall be entitled to receive
a reasonable fee for management of the Property. If Grantor is an occupant
of the Property, Beneficiary has the right to require Grantor to pay rent at
fair market rates and the right to remove Grantor from Property if Grantor
fails to pay rent.
6. SALE OF PROPERTY AFTER DEFAULT. Following a default and the
foreclosure of this Deed of Trust, either judicially or nonjudicially, the
Collateral may be sold separately or as a whole, at the option of Beneficiary.
In the event of a trustee's sale of the Collateral pursuant to the power of
sale granted herein, Beneficiary hereby assigns its security interest in the
personal property Collateral to the trustee. Beneficiary may also realize on
the personal property Collateral in accordance with the remedies available
to secured parties under the Uniform Commercial Code or at law. In the event
of a trustee's sale, Grantor, and the holder of any subordinate liens or
security interest with actual or constructive notice hereof, waive any
equitable, statutory or other right they may have to require marshaling of
assets in connection with the exercises of any of the remedies permitted by
applicable law or provided herein, or to direct the order in which any of
the Collateral will be sold in the event of any sale under this Deed of
Trust or foreclosure in the inverse order of alienation.
7. FORECLOSURE OF LESSEE'S RIGHTS-SUBORDINATION. Beneficiary shall
have the right, at its option, to foreclose this Deed of Trust subject to
the rights of any lessees of the Property. Beneficiary's failure to
foreclose against any lessee shall not be asserted as a claim against
Beneficiary or as a defense against any claim by Beneficiary in any action
or proceeding. Beneficiary at any time may subordinate this Deed of Trust to
any or all of the Leases except that Beneficiary shall retain its priority
claim to any condemnation or insurance proceeds.
8. REPAIRS DURING REDEMPTION. In the event of a judicial foreclosure the
purchaser during any redemption period may make such repairs and alterations
to the Property as may be reasonably. necessary for the proper operation,
care, preservation, protection and insuring of the Property. Any sums so paid,
together with interest from the date of the expenditure at the rate provided
in the judgment, shall be added to the amount required to be paid for
redemption of the Property.
ARTICLE VI
1 . ADDITIONAL SECURITY DOCUMENTS. Grantor shall within fifteen (15) days
after request by Beneficiary execute and deliver any financing statement,
renewal, affidavit, certificate, continuation statement, or other document
Beneficiary may request in order to perfect, preserve, continue, extend, or
maintain security interests or liens granted herein to Beneficiary and the
priority of such security interests or liens. Grantor shall pay all costs and
expenses incurred by Beneficiary in connection with the preparation,
execution, recording, filing, and refiling of any such document.
-13-
2. RECONVEYANCE AFTER PAYMENT. Upon written request of Beneficiary
stating that all obligations secured by this Deed of Trust have been paid,
Trustee shall reconvey, without warranty, the Collateral then subject to the
lien of this Deed of Trust. Grantor shall pay any costs, trustee's fees and
recording fees incurred in so reconveying the Property.
3. NONWAIVER OF TERMS AND CONDITIONS. Time is of the essence with
respect to performance ofthe obligations under the Loan Documents.
Beneficiary's failure to require prompt enforcement of any such obligation
shall not constitute a waiver of the obligation or any subsequent required
performance of the obligation. No term or condition of this Deed of Trust or
any other Loan Documents may be waived, modified or amended except by a
written agreement signed by Grantor and Beneficiary. Any waiver of any term
or condition of the Loan Documents shall apply only to the time and occasion
specified in the waiver and shall not constitute a waiver of the term or
condition at any subsequent time or occasion.
4. WAIVERS BY GRANTOR. Without affecting any of Grantor's obligations
under the Loan Documents, Grantor waives the following: (a) any right to
require Beneficiary to proceed against any specific party liable for sums
due under the Loan Documents or to proceed against or exhaust any specific
security for sums due under the Loan Documents; (b) notice of new or
additional indebtedness of any Grantor or any other party liable for sums
due under the Loan Documents to Beneficiary; (c) any defense arising out of
Beneficiary entering into additional financing or other arrangements with
any Grantor or any other party liable for sums due under the Loan Documents
and any action taken by Beneficiary in connection with any such financing or
other arrangements or any pending financing or other arrangements; (d) any
defense arising out of the absence, impairment, or loss of any or all rights
of recourse, reimbursement, contribution or subrogation or any other rights or
remedies of Beneficiary against any Grantor or any other party liable for sums
due under the Loan Documents or any Collateral; and (e) any obligation of
Beneficiary to see to the proper use and application of any proceeds advanced
pursuant to the Loan Documents.
5. RIGHT OF SUBROGATION Beneficiary is subrogated to the rights,
whether legal or equitable, of all beneficiaries, mortgagees, lienholders
and owners directly or indirectly paid off or satisfied in whole or in part
by any proceeds advanced by Beneficiary under the Loan Documents, regardless
of whether such parties assigned or released of record their rights or liens
upon payment.
6. JOINT AND SEVERAL LIABILITY. If there is more than one Grantor of
this Deed of Trust, their obligations shall be joint and several.
7. STATEMENT OF AMOUNT OWING. Grantor within fifteen (15) days after
request by Beneficiary will furnish Beneficiary a written statement of the
amount due under the Loan Documents, any offsets or defenses against the
amount claimed by Grantor, and such other factual matters as Beneficiary may
reasonably request.
8. BOOKS AND RECORDS; FINANCIAL STATEMENTS.
(a) Grantor will keep and maintain at Grantor's principal place of
business which is East 0000 Xxxxxxxx Xxxxxx, Xxxxxxx, XX 00000, or such
other place as Beneficiary may approve in writing, books of accounts and
records adequate to reflect correctly the results of the operation of the
Property and copies of all written contracts, leases and other instruments
which affect the Property. Such books, records, contracts, leases and other
instruments shall be subject to examination, inspection and copying at any
reasonable time by Beneficiary. Except as otherwise agreed in writing by
Beneficiary, Grantor shall provide to Beneficiary within ninety (90) days
after the end of each of Grantor's fiscal years (or within twenty (20) days
of Beneficiary's written request therefor if Grantor is in default), for
each Grantor, for each general partner of Grantor if Grantor is a partnership,
and for each guarantor of all or any of the Secured Obligations, a complete
and current financial statement, together with a statement of income and
expenses of the Property and a statement of changes in financial position
with respect to the Property for the prior year, each in reasonable detail
and certified by Grantor, the general partner or the guarantor, as the case
may be. All financial statements shall be prepared in accordance with
generally accepted accounting principles consistently applied, or such other
accounting practices as Lender may approve. At the same time, Grantor shall
also furnish a current rent roll for the Property, certified by Grantor,
which shall include such
-14-
information as Beneficiary may require, including the name of each tenant,
the lease expiration date, the monthly rent, the date to which rent has
been paid, and any deposits or prepaid rent Grantor is holding. In addition
to the foregoing, unless otherwise agreed in writing by Beneficiary, within
one hundred twenty (120) days after the end of each tax year of Grantor and
each guarantor of all or any of the Secured Obligations, Grantor will
provide Beneficiary with a copy of the United States federal income tax
return filed by Grantor and each guarantor for his, her or its tax year most
recently ended.
(b) All financial statements shall be prepared in accordance with
generally accepted accounting principles, consistently applied, or shall
otherwise be prepared in a manner acceptable to Beneficiary. Grantor's
compliance with these provisions shall not limit or affect Grantor's
obligations to comply with financial, tax and operation covenants and
reporting requirements under any other agreement between Grantor and
Beneficiary whether or not such other agreement is related to the Secured
Obligations. If any of the reporting requirements in this Section 8 are
inconsistent with the reporting requirements in any such other agreement,
the reporting requirements in such other agreement shall control.
9. APPRAISALS. In the event of a default Beneficiary may obtain a
current regulatory conforming appraisal of the Collateral. In addition,
appraisals may be commissioned by Beneficiary when required by laws and
regulations which govern Beneficiary's lending practices. The cost of all
such appraisals (and related internal review fees and costs) will be paid by
Grantor within fifteen ( 15) days after request by Beneficiary.
10. INVASION OF PREPAYMENT FEE. If Grantor is in default, whether
Beneficiary has accelerated the maturity of the indebtedness or not, any
tender of payment sufficient to satisfy all sums due under the Loan
Documents made at any time prior to foreclosure sale shall constitute an
evasion of lllc prepaylnent terms of the Note, if any, and shall be deemed a
voluntary prepayment. Any such payment, to the extent permitted by law,
shall include the additional payment required under the prepayment fee
provision in the Note, if any, or if at that time prepayment is not permitted,
then such payment, to the extent permitted by law, will include an
additional payment of five percent (5%) of the then principal balance.
11. PAYMENT OF NEW TAXES. If any federal, state or local law is passed
subsequent to the date of this Deed of Trust which requires Beneficiary to pay
any tax because of this Deed of Trust or the sums due under the Loan Documents
(excluding income taxes), then Grantor shall pay to Beneficiary on demand any
such taxes if it is lawful for Grantor to pay them, or, in the alternative
Grantor may repay all sums due under the Loan Documents plus any prepayment
fee within thirty (30) days of such demand. If it is not lawful for Grantor to
pay such taxes, then at its option Beneficiary may declare a default under the
Loan Documents.
12. IN-HOUSE COUNSEL FEES. Whenever Grantor is obligated to pay or
reimburse Beneficiary or Trustee for any attorneys' fees, those fees shall
include the allocated costs for services of in-house counsel.
13. NOTICES. Any notice given by Grantor, Trustee or Beneficiary shall
be in writing and shall be effective (1) on personal delivery to the party
receiving the notice or (2) on the third day after deposit in the United
States mail, postage prepaid with return receipt requested, addressed to the
party at the address set forth above (or such other address as a party may
specify by written notice given pursuant to this paragraph), or with respect
to the Grantor, to the address at which Beneficiary customarily or last
communicated with Grantor.
14. CONTROLLING DOCUMENT. In the event of a conflict or inconsistency
between the terms and conditions of this Deed of Trust and the terms and
conditions of any other of the Loan Documents (except for any separate
assignment of the Rents and/or the Leases and any loan agreement which shall
prevail over this Deed of Trust), the terms and conditions of this Deed of
Trust shall prevail.
-15-
15. INVALIDITY OF TERMS AND CONDITIONS. If any term or condition of
this Deed of Trust is found to be invalid, the invalidity shall not affect
any other term or condition of the Deed of Trust and the Deed of Trust shall
be construed as if not containing the invalid term or condition .
16. LEGISLATION AFFECTING BENEFICIARY'S RIGHTS. If enactment or
expiration of applicable laws has the effect of rendering any provision of
the Note or this Deed of Trust unenforceable according to its terms,
Beneficiary, at its option, may require immediate payment in full of all
sums secured by this Deed of Trust and may invoke any remedies permitted
herein.
l7. RULES OF CONSTRUCTION. This Deed of Trust shall be construed so that,
whenever applicable, the use of the singular shall include the plural, the use
of the plural shall include the singular, and the use of any gender shall be
applicable to all genders and shall include corporations, partnerships,
limited partnerships, limited liability companies and other forms of entities.
This Deed of Trust inures to the benefit of, and binds all parties named
herein and their successors and assigns. The headings to the various sections
have been inserted for convenience of reference only and shall not be used to
construe this Deed of Trust.
18. APPLICABLE LAW. The Loan Documents shall be governed by and
construed in accordance with the laws of the State of Washington.
GRANTOR:
THE COEUR D'ALENES COMPANY,
an Idaho corporation
By Xxxxxxx Xxxxxxxxx
-----------------
Its: Treasurer
---------
STATE OF WASHINGTON )
)SS
COUNTY OF Spokane )
On this day personally appeared before me Xxxxxxx Xxxxxxxxx to me known
(or proven on the basis of satisfactory evidence) to be the Treasurer of THE
COEUR D'ALENES COMPANY, an Idaho corporation, the corporation that executed the
within and foregoing instrument, and acknowledged said instrument to be the
free and voluntary act and deed of said corporation, for the uses and purposes
therein mentioned, and on oath stated that __he was authorized to execute said
instrument.
GIVEN UNDER my hand and of official seal this 5th day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
----------------------
[SEAL] (Print Notary Name) Xxxxxxxx X. Xxxxxx
Notary Public in and for the State of Washington
residing at Greenacres WA
My appointment expires 8-27-99
-16-
REQUEST FOR FULL RECONVEYANCE
To be used only when all obligations have been paid
under the Note and this Deed of Trust
TO: TRUSTEE
The undersigned is the legal owner and holder of the Note and all other
indebtedness secured by the within Deed of Trust. Said Note, together with
all other indebtedness secured by said Deed of Trust, has been fully paid and
satisfied; and you are hereby requested and directed, on payment to you of
any sums owing to you under the terms of said Deed of Trust, to cancel said
Note above mentioned and all other evidence of indebtedness secured by said
Deed of Trust delivered to you herewith, together with said Deed of Trust,
and to reconvey, without warranty, to the parties designated by the terms of
said Deed of Trust, all the estate now held by you thereunder.
Dated____________________________________________________________
Mail reconveyance to:____________________________________________
-17-
SCHEDULE A
THIS SCHEDULE IS PART OF THE DEED OF TRUST DATED DECEMBER 20, 1995, BETWEEN
THE COEUR D'ALENES COMPANY, AN IDAHO CORPORATION, AS GRANTOR, RAINIER CREDIT
COMPANY, AS TRUSTEE, AND SEATTLE-FIRST NATIONAL BANK, A NATIONAL BANKING
ASSOCIATION, AS BENEFICIARY
PROPERTY ADDRESS: EAST 0000 XXXXXXXX XXXXXX, XXXXXXX, XX 00000
LEGAL DESCRIPTION:
BLOCKS 000 XXX 000, XXXX XXXX SYNDICATE ADDITION, ACCORDING TO PLAT RECORDED
IN VOLUME "C" OF PLATS, PAGE 73, IN THE CITY OF SPOKANE, SPOKANE COUNTY,
WASHINGTON.
TOGETHER WITH VACATED SPRINGFIELD AVENUE ADJACENT TO SAID PREMISES.
-18-
+
[LOGO]
Loan No. 604938 and 453817-9
CONSTRUCTION LOAN AGREEMENT
This Agreement is made as of December 20, 1995, between SEATTLE-FIRST
NATIONAL BANK a national banking association ("LENDER"), and THE COEUR D'ALENES
COMPANY, an Idaho corporation ("BORROWER").
RECITALS:
A. Borrower has requested that Lender make a loan to Borrower (the "LOAN")
to be secured by certain real property (the "PROPERTY") commonly known as
East 0000 Xxxxxxxx Xxxxxx, Xxxxxxx, XX 00000 located in Spokane County,
Washington. The proceeds of the Loan will be used to pay a portion of the cost
of making certain improvements more particularly described as follows: a
90,448 square foot industrial warehouse building (the "IMPROVEMENTS"). The
Property and the Improvements are collectively referred to in this Agreement as
the "Project".
B. Lender is willing to make the Loan to Borrower on the terms and
conditions set forth in this Agreement.
AGREEMENT:
In consideration of the mutual covenants contained in this Agreement,
Borrower and Lender agree as follows:
1. LOAN. The principal amount of the Loan will be ONE MILLION SIX
HUNDRED EIGHTY-EIGHT THOUSAND AND NO/100 DOLLARS ($1,688,000.00). The Loan
will be evidenced by a Promissory Note (the "NOTE") which is being executed
by Borrower with this Agreement. The payment and interest terms of the Loan
are set forth in the Note. The terms of the Note are incorporated into this
Agreement by this reference. The Loan will mature, and be due and payable in
full ten (10) months from the first day of the first calendar month following
the initial advance of Loan proceeds. The last day of the term of the Loan is
referred to in this Agreement as the "MATURITY DATE". The Loan shall be due
and payable in full on the Maturity Date, as the same may be extended
pursuant to the Note.
2. LOAN DOCUMENTS. In addition to the Note and this Agreement, the Loan
will be evidenced, guaranteed and secured by the following documents, and any
other documents which Lender may require (collectively with this Agreement, the
Note, and all extensions, modifications and renewals of any such documents, the
"LOAN DOCUMENTS"), all of which must be acceptable to Lender in form and
content:
2.1 DEED OF TRUST. A Deed of Trust, Security Agreement and Fixture
Filing with Assignment of Leases and Rents (the "DEED OF TRUST") which creates
or constitutes, as applicable (a) a first priority lien on fee simple title to
the Property; (b) a first priority security interest in all fixtures and
tangible and intangible personal property used in the development, operation,
maintenance or management of the Project; (c) a fixture filing under the
Washington Uniform Commercial Code; and (d) a present assignment of all leases,
rents, revenues and other cash received or receivable with respect to the
Project.
2.2 FINANCING STATEMENTS. Such Uniform Commercial Code financing
statements ("FINANCING STATEMENTS") as Lender may require to perfect any
security interests granted to Lender under the Deed of Trust, this Agreement or
any other Loan Document.
1
2.3 GUARANTEES. A guaranty or guarantees of the payment and
performance of Borrower's obligations under the Loan Documents (each a
"Guarantor" and if more than one person or entity, collectively
"GUARANTORS").
2.4 ASSIGNMENT OF CONSTRUCTION CONTRACT. Architect's Contract and
Plans and Specifications required by Lender, an assignment of the general
contract for the construction of the improvements, between Borrower and its
contractor ("GENERAL CONTRACTOR"), an assignment of the architectural contract
for the Improvements with the Project architect ("ARCHITECT"), and an assignment
of the plans and specifications for the Improvements, and such consents to such
assignments as Lender may require.
3. LOAN FEE. In consideration of Lender's execution of this Agreement,
which evidences Lender's commitment to make the Loan on the terms and conditions
of this Agreement and the other Loan Documents, Borrower shall pay Lender a
loan fee in the amount of one percent (l .000%) of the amount of Loan (the
"LOAN FEE"). One-half (l/2) of the Loan Fee shall be fully earned by Lender upon
the execution of this Agreement by both parties, and is due and payable without
condition on the date of the first disbursement of Loan proceeds, or sixty (60)
days from the date of this Agreement, whichever is earlier. The remainder of the
Loan Fee shall be fully earned by Lender upon the conversion of the Loan to a
permanent loan in accordance with the terms of the Note, and shall be due and
payable in full on the date of such conversion.
4. PRE-CLOSING REQUIREMENTS. Prior to and as a condition precedent to the
closing and funding of the Loan, each of the conditions set forth below must be
met to Lender's satisfaction, and Borrower must meet to Lender's satisfaction
all other conditions to the closing and initial funding of the Loan as may be
specified in writing by Lender to Borrower pursuant to a loan commitment, term
sheet, exhibit letter or other written instrument. For purposes of this
Agreement, the term "closing" means the date the Deed of Trust is recorded and
the conditions to the initial advance of Loan proceeds are satisfied. All
documents and instruments referred to below or in any other such written
instrument must be acceptable to Lender in form and content.
4.1 LOAN DOCUMENTS. All Loan Documents shall have been executed and
delivered to Lender by Borrower, Guarantor(s) and such other persons or entities
as Lender may require, the Deed of Trust shall have been duly recorded in the
real property records of the county in which the Property is located, the
Financing Statements shall have been filed in all places necessary to perfect
the liens and security interests created by the Deed of Trust and other Loan
Documents, and any other Loan Documents to be recorded or filed shall have been
duly recorded and filed in the appropriate recording and filing offices.
4.2 LOAN FEE. Borrower shall have paid the Loan Fee.
4.3 CERTIFICATE AND INDEMNITY. Borrower shall have executed and
delivered to Lender a Certificate and Indemnity Agreement Regarding Building
Laws and Hazardous Substances (the "CERTIFICATE AND INDEMNITY").
4.4 TITLE INSURANCE. Lender shall have received an ALTA extended
coverage lender's policy of title insurance (the "TITLE POLICY") from a title
insurance company acceptable to Lender, in an amount not less than the maximum
principal amount of the Loan, insuring the Deed of Trust as a first lien on
Borrower's interests in the Property, subject only to liens, encumbrances and
other exceptions to title approved in writing by Lender and set forth in the
Title Policy. The Title Policy shall contain such title insurance endorsements
and reinsurance or coinsurance agreements as Lender may reasonably require.
4.5 UCC SEARCHES. Lender shall have received current uniform
commercial code searches made in the office of the Department of Licensing of
the State of Washington, and such other places as Lender may require, covering
Borrower and such other persons and entities as Lender may require, and showing
no filings related to or which could relate to the Project, or any other
collateral for the Loan, other than filings made pursuant to the Loan Documents
or otherwise approved by Lender.
2
4.6 FINANCIAL CONDITION. Lender shall be satisfied that the financial
condition and credit of Borrower and each Guarantor and all information relating
to the Project and its condition are as represented to Lender without any
material adverse change.
4.7 CONSTRUCTION MATTERS. Lender shall have approved the General
Contractor and received and approved the Construction Contract between Borrower
and General Contractor for the improvements (the "CONSTRUCTION CONTRACT"), and
if required by Lender, Lender shall have received a performance and payment bond
in an amount and otherwise acceptable to Lender, and a list of all
subcontractors and materialmen who are expected to provide labor or material in
connection with the Project.
4.8 PERMITS. Lender shall have received and approved copies of all
building and other governmental permits and approvals necessary for Borrower to
construct the Improvements and complete the Project.
4.9 LITIGATION. There shall be no litigation pending against Borrower
or any Guarantor, or any partner in Borrower, which in Lender's opinion could or
does affect Borrower's ability to complete the Project or Borrower's or any
guarantor's ability to otherwise perform all of the terms and provisions of this
Agreement, the other Loan Documents and the Certificate and Indemnity.
4.10 OTHER CONDITIONS. All other provisions of this Agreement or any
other Loan Document to be complied with prior to the closing and initial funding
of the Loan shall have been complied with, and all of the representations and
warranties of Borrower and the other Loan Documents in this Agreement shall be
true and correct in all material aspects.
If Lender disburses funds without requiring the satisfaction of each of the
foregoing conditions, Borrower's obligation to meet the unsatisfied conditions
shall not be deemed waived (unless specifically waived in writing by Lender) and
Lender may require compliance with each of such conditions before further Loan
proceeds are disbursed.
5. CONSTRUCTION COVENANTS.
5.1 PLANS AND SPECIFICATIONS; PROJECT BUDGET. Borrower shall complete
the Improvements and the Project in accordance with plans and specifications
submitted to and approved in writing by Lender (the "PLANS AND SPECIFICATIONS"),
and a budget (the "PROJECT BUDGET") approved in writing by Lender containing a
detailed breakdown of the total costs of constructing the Improvements and
completing the Project. Unless otherwise agreed in writing by Lender, the Plans
and Specifications and the Project Budget shall be submitted to and approved by
Lender prior to the closing and initial funding of the Loan. The Loan proceeds
shall be allocated to various Project costs as shown in the Project Budget. The
line items in the approved Project Budget may be adjusted and reallocated from
time to time by Borrower, subject to the prior written approval of Lender.
Lender also may initiate and determine reallocations of line items in the
Project Budget from time to time when Lender determines such reallocations to be
reasonable or appropriate.
5.2 COMPLETION OF PROJECT. Borrower shall cause the Project to be
completed in a good and workmanlike manner in accordance with the Plans and
Specifications, and in compliance with the terms and conditions of the building
permits and all other permits and approvals issued for the Project by any
governmental authority, and the provisions of any applicable covenants,
conditions or restrictions, free and clear of all claims, liens and encumbrances
other than the Deed of Trust and such other encumbrances as Lender may approve
in writing. Borrower also shall comply with all applicable federal, state and
local laws, including without limitation federal, state and local environmental,
shorelines management and hazardous waste laws.
5.3 COMMENCEMENT AND COMPLETION. Construction of the Improvements has
commenced (or will commence within thirty (30) days after the date of this
Agreement), and the Improvements and the Project shall be completed within
seven (7) months from the date of this Agreement, or sooner as required by any
lease or other agreement or governmental permit or approval by which Borrower or
the Project is bound. The Project shall be deemed completed upon the
satisfaction of the conditions to final disbursement of Loan proceeds set forth
in Section 7 below.
3
5.4 CHANGES IN PLANS AND SPECIFICATIONS: CHANGE ORDERS. Borrower
shall provide Lender with notice of all changes in the Plans and Specifications,
changes to the terms of the Construction Contract, orders for extra work, or
other changes to the Project. Unless otherwise agreed by Lender, all changes to
the Plans and Specifications or the Project (other than minor changes which do
not affect the cost of the Project or the scheduled completion date) shall be
made by a written change order signed by Borrower and General Contractor.
Lender's prior written approval shall be required for (a) any single change
order or modification which will result in an extension of the completion date
of the Project if more than seven (7) days or which will result in an increase
or decrease of more than $7,000.00 (or such other amount as Lender may now or
hereafter approve in writing) of the direct construction costs specified in the
approved Project Budget ("CONSTRUCTION COSTS"), (b) any change order or
modification which together with the aggregate of all previous change orders or
modifications (whether or not previously approved by Lender) will result in a
net cumulative increase of the completion date of the Project if more than
thirty (30) days or which will result in a net cumulative increase or decrease
of more than $30,000.00 (or such other amount as Lender may now or hereafter
approve in writing) of the Construction Costs. Borrower will not permit the
performance of any work pursuant to any change order unless and until Borrower
has received the approval of Lender, if such approval is required pursuant to
this paragraph. Borrower shall provide Lender with copies of all change orders
and modifications, irrespective of amount, whether or not Lender's prior
approval is required pursuant to this paragraph. If a change order is made
without Lender's consent and such consent is required pursuant to this
paragraph, Lender shall have no obligation to disburse any Funds to pay for
costs associated with the change order.
5.5 ABANDONMENT OF CONSTRUCTION. If construction of the Improvements
is at any time abandoned or discontinued for fifteen (15) consecutive days or
more, or if Lender in good faith determines the work is not being performed in
accordance with the approved Plans and Specifications and Construction Contract,
Lender at its option, may enter onto the Property (or designate a third party to
enter onto the Property) to complete the construction or correct any work
improperly done or replace any defective material. If Lender exercises the
foregoing option, Lender may employ such workmen and furnish such materials as
it believes are necessary or appropriate to complete the Improvements or correct
any errors or defects in construction or workmanship, or Lender may declare a
default under this Agreement. All costs incurred by Lender pursuant to this
paragraph, including a reasonable sum for supervision, attorneys' fees and all
related costs and expenses, shall be deemed additional advances to Borrower and
secured by the Deed of Trust and the other Loan Documents and by any other
collateral for the Loan, and added to the unpaid principal balance of the Loan
(even if the costs so incurred, together with prior advances of Loan proceeds,
cause the outstanding principal balance to exceed the maximum amount of the Loan
set forth above). On demand, Borrower shall pay all costs and expenses expended
by Lender pursuant to this paragraph. The fifteen (15) day period set forth
above shall be extended one (l) day for each day that the abandonment or
discontinuation of construction is caused by fire, earthquake or other acts of
God, strikes, lockout, acts of public enemy, riot, insurrection or governmental
regulation of the sale or transportation of materials, supplies or labor, or any
other cause beyond the reasonable control of Borrower; provided, in no event
shall such fifteen (15) day period be extended to a period of more than
sixty (60) days, unless otherwise agreed in writing by Lender.
6. EQUITY. Prior to the initial advance of Loan proceeds, Lender shall
have received evidence satisfactory to it that Borrower has "EQUITY" in the
Project in an amount equal to the difference between (a) the total cost of
the Project, as shown in the Project Budget approved by Lender, and (b) the
amount of the Loan. Equity may be in the form of either prepaid costs in the
approved Project Budget, paid by Borrower with its own funds and verified by
Lender, or cash deposited with Lender. All cash deposited by Lender will be
advanced by Lender pursuant to the terms of this Agreement prior to the
disbursement of Loan funds.
7. DISBURSEMENTS. This Section 7 shall govern the disbursement of Loan
proceeds and all funds deposited with Lender pursuant to this Agreement,
including any equity or other funds deposited with Lender pursuant to this
Agreement (collectively the "FUNDS"). Borrower authorizes Lender to pay directly
from the Funds, the Loan Fee and Lender's expenses for which Borrower is liable
under this Agreement or any other Loan Document.
4
7.1 GENERAL CONDITIONS TO DISBURSEMENTS. Each disbursement of Funds at
the request of Borrower is subject to the following general conditions:
(a) Neither the Improvements nor any other part of the Project shall
have been materially damaged by fire or other casualty, and there shall be no
eminent domain or condemnation proceeding pending or threatened against the
Project. This condition shall be deemed satisfied if Lender has received
insurance or condemnation proceeds or a cash deposit from Borrower sufficient
in Lender's judgment to pay the cost of all repairs necessary as a result of
the casualty or condemnation and any related costs or expenses.
(b) Lender shall have received, at Borrower's expense, an endorsement
to the Title Policy, in form and content acceptable to Lender, insuring the
continued first lien priority of the Deed of Trust.
(c) Lender shall have received, at Borrower's expense, upon
completion of the foundations of the Improvements, a foundation endorsement
to the Title Policy, in form and content acceptable to Lender, showing no
encroachments of the foundations onto other property.
(d) Lender must be satisfied that the Loan is "in balance" pursuant
to Section 7.6 below or Borrower must have deposited the additional Funds
with Lender required pursuant to such section of this Agreement.
(e) Lender is not prohibited from disbursing Funds under any
applicable lien laws or stop notice statutes or otherwise.
(f) Borrower is not in default under this Agreement or any other
Loan Document or under the Certificate and Indemnity, and no event or
circumstance then exists which with notice, the passage of time or both would
constitute a default under this Agreement, any other Loan Document or the
Certificate and Indemnity.
(g) No legal or administrative proceeding challenging the validity
of or seeking to enjoin, set aside, review or otherwise challenge any
governmental permit or approval applicable to the Project shall be pending
or threatened.
Unless all the foregoing conditions are met to Lender's satisfaction, Lender
shall have no obligation to make any disbursement of Funds requested by
Borrower; however, Lender may elect to make an advance of Funds
notwithstanding that any one or more of the foregoing conditions is not
satisfied, and by doing so Lender shall not be deemed to have waived its
right to require the satisfaction of any such conditions with respect to
any other advance of Funds. Unless otherwise agreed in writing by Lender,
throughout the term of the Loan, Borrower shall maintain a checking account
(the "Loan Account") with Lender into which Loan proceeds and other Funds
will be deposited and from which any Loan payments that Borrower is
required to make will be automatically withdrawn.
7.2 DISBURSEMENTS FOR CONSTRUCTION COSTS. Borrower may request
disbursements of Funds to pay direct construction costs provided for in the
Project Budget once a month. All requests for payment of Construction Costs
shall be pursuant to a draw request ("DRAW REQUEST"). Each Draw Request
shall be on an AIA form of Application and Certificate for Payment (or
other form approved by Lender), signed by General Contractor, and Borrower or
Architect, as required by Lender. Lender shall make disbursements pursuant to
each Draw Request within seven (7) business days after Lender's receipt and
approval of the Draw Request and any supplementary documentation or
information required by Lender, and subject to the terms and conditions of
Section 7 of this Agreement. Unless otherwise agreed in writing by Lender,
each Draw Request shall be accompanied by the following, all of which must
be acceptable to Lender:
(a) A Certificate of Job Progress signed by Borrower and General
Contractor stating the percentage of the Project completed through the date
payment is requested.
(b) If requested by Lender, invoices (or other reasonable evidence)
substantiating the Construction Costs covered by the Draw Request.
5
(c) Executed acknowledgments of payment and releases of liens
(through the date covered by the immediately preceding monthly advance) from
General Contractor and all laborers, subcontractors and materialmen
performing labor or services or supplying materials in connection with the
Project.
Lender will withhold from each advance of Construction Costs an amount
(the "RETENTION") equal to ten percent (10%) (or such other amount as may be
set forth in the Construction Contract and approved in writing by Lender) of
the amount of the Construction Costs for which disbursement is requested.
Unless otherwise agreed in writing by Lender, the amount of the Retention
shall be held by Lender until the conditions for final advance set forth
below are satisfied. If a disbursement is requested to pay for materials
stored off-site, prior to making the disbursement Lender must receive (i) a
copy of a xxxx of sale or other acceptable evidence establishing that such
materials were purchased free and clear of liens and encumbrances and not
pursuant to a conditional sales contract, (ii) evidence the materials are
stored at a suitable location acceptable to Lender, and are insured against
damage or destruction for the full insurable value under a policy of
insurance which names Lender as an additional loss payee, and (iii) evidence
the materials are segregated from materials and equipment not intended to be
incorporated into the Project.
7.3 DISBURSEMENTS FOR OTHER COSTS.
(a) INTEREST. If there is an interest reserve in the Project Budget,
prior to completion of the Improvements (and after completion of the
Improvements to the extent the net operating income from the Project is
insufficient to pay interest due on the Note), Lender will make monthly
disbursements of Funds from the interest reserve set forth in the Project
Budget to pay interest on the Note. If in Lender's opinion, the undisbursed
balance of the Loan allocated to interest in the Project Budget (plus any
anticipated net operating income of the Project) is not sufficient to pay
interest on the Note as it comes due, on demand, Borrower shall pay the
interest from its own monies (not Loan proceeds or other Funds) or shall
deposit additional funds with Lender to be added to the interest reserve, at
Lender's option. The foregoing is not intended to alter or limit Borrower's
obligation to make the monthly payments on the Note as the same come due if
the interest reserve is not adequate or if Lender otherwise is not required
to make such disbursements.
(b) NON-CONSTRUCTION COSTS. Borrower may from time to time request
the disbursement of Funds to pay costs other than Construction Costs if such
other costs are included in the Project Budget, and the disbursement request
is otherwise approved by Lender. With each request, Borrower will provide
Lender with such evidence as Lender may require verifying the amount and
purpose of the costs for which disbursement is requested. Prior to disbursing
Funds to any person or entity for Project management or development fees,
real estate fees or commissions or otherwise, Lender shall have received,
reviewed and approved executed copies of the applicable agreement providing
for the payment of such fees or commissions, and Lender shall be reasonably
satisfied that the person or entity to be paid has duly performed the
services for which payment is requested.
7.4 INSPECTIONS BY LENDER. At Lender's option, Lender may retain, at
Borrower's expense, an architect, structural engineer or other construction
consultant (the "CONSULTANT") to inspect the Project, review Draw Requests,
the Construction Contract, the Plans and Specifications, the Project Budget
and such other documents or information as Lender may require, visit the
Project and perform such other duties as Lender deems necessary or desirable
in connection with Lender's administration of the Loan. The Consultant may
make periodic inspections of the Improvements during construction to review
and comment on construction progress and percentage of completion, conformity
of the work with the Plans and Specifications, activity and coordination
among trades and quality of workmanship, and the accuracy of the statement of
percentage of completion reflected in any Certificate of Job Progress
submitted to Lender. Any inspections by Lender or the Consultant shall be
solely for the purpose of protecting the interests of Lender, and such
inspections shall not be construed as a representation to Borrower or any
other person or entity that there has been or will be strict compliance on
the part of any contractors or subcontractors with the Plans and
Specifications or construction of the Improvements is or will be free from
faulty materials or workmanship. If the Consultant does not approve a
Certificate of Job Progress, or any other materials or information submitted
to Lender with a Draw Request, Lender will have no obligation to make the
requested advance in an amount greater than the amount approved by the
Consultant.
6
7.5 AMOUNT OF DISBURSEMENTS. Lender shall have no obligation to make an
advance if (a) the percentage of Construction Costs in the Project Budget
which has already been disbursed is greater than the percentage of completion
of the Project, as certified to Lender in any Certificate of Job Progress and
verified by Lender or the Consultant, (b) the percentage of any Construction
Cost line item in the Project Budget which is already paid out is greater
than the percentage of completion of that line item, or (c) in Lender's
reasonable opinion the value of the Property as then improved is not adequate
security for the Loan.
7.6 LOAN BALANCING. Lender shall have no obligation to make a requested
advance if in Lender's reasonable opinion the Loan is not "IN BALANCE"; i.e.,
the undisbursed balance of the Loan, plus any undisbursed Funds previously
deposited by Borrower with Lender, if any, are not sufficient to pay all
costs necessary to complete the Project (including without limitation the
payment of interest on the Loan) in accordance with the approved Plans and
Specifications and the approved Project Budget, free and clear of all liens,
encumbrances and conditional sales contracts, whether the deficiency is
attributable to changes in the work or in the Plans and Specifications or to
any other cause. If at any time Lender determines the Loan is not in balance,
within five (5) days after demand, Borrower will deposit with Lender the
amount necessary to "balance" the Loan, and all Funds so deposited with
Lender shall be held and disbursed by Lender in accordance with this
Agreement prior to the disbursement of any additional Loan proceeds. If
Lender makes such demand, Lender shall have no obligation to make further
disbursements of Funds until such additional funds are deposited with Lender
by Borrower. Each Draw Request or other request for disbursement submitted
to Lender will constitute Borrower's representation and warranty to Lender
that the Loan is "in balance".
7.7 USE AND APPLICATION OF FUNDS. Funds disbursed by Lender at Borrower's
request shall be used only to pay costs associated with the Project, and only
in accordance with Borrower's Draw Requests or other requests for
disbursement. Lender shall not be obligated to advance more than one
hundred percent (100%) of the actual costs of the Project as shown in the
Project Budget. Advances of Funds shall be made to Borrower, or at Lender's
option, directly to the contractors, materialmen, laborers and
subcontractors involved in the Project. Lender shall have no obligation to
assure that Funds advanced to Borrower or others are applied against the cost
of the Project. Borrower accepts full responsibility for the proper
application of all Funds advanced by Lender at Borrower's request. Lender may
rely solely on Draw Requests or other disbursement requests submitted by
Borrower or its agents and upon other affidavits, statements or reports
submitted by Borrower or its agents in making advances of Funds. Borrower
shall defend, indemnify and hold Lender harmless from any losses, demands,
claims, attorneys' fees and expenses which may arise out of the
misapplication or misuse of Loan proceeds (or other Funds) by Borrower or by
any other person paid at Borrower's direction.
7.8 FINAL DISBURSEMENT. The final disbursement of Funds, including the
Retention, shall be made only if the conditions set forth below are met to
Lender's satisfaction. Furthermore, the amount of the final disbursement
shall be subject to Lender's approval.
(a) The Improvements and the Project are completed in accordance
with the Plans and Specifications as confirmed by Architect, and Lender or
the Consultant, and if requested by Lender, Lender shall have received
as-built Plans and Specifications for the Project.
(b) Lender shall have received, at Borrower's expense, an
endorsement to the Title Policy insuring the lien-free completion of the
Project, without exceptions other than those previously approved by Lender.
(c) If requested by Lender, Lender shall have received an as-built
survey of the Project and an endorsement to the Title Policy eliminating
title exceptions regarding possible encroachments and/or violations of
easement rights.
(d) If requested by Lender, Lender shall have received copies of all
licenses, permits and certificates necessary for the lawful use and occupancy
of the Project, including but not limited to a copy of the final certificate
of occupancy for the Project, which shall be unconditional unless otherwise
agreed by Lender, or other evidence acceptable to Lender that the Project is
completed and accepted by all necessary governmental authorities.
7
(e) If requested by Lender, Lender shall have received a final
accounting of Project costs from Borrower and/or General Contractor.
(f) Lender shall have received fully executed lien releases from
General Contractor and all persons or entities performing labor or services
or supplying materials in connection with the Project, or Borrower shall have
provided Lender with an appropriate surety bond from a surety acceptable to
Lender or affirmative title insurance coverage with respect to potential
laborers', mechanics' or materialmens' liens.
7.9 EXPENSES, FEES AND INTEREST. Notwithstanding any other provision of
this Agreement, Lender may elect to use Funds to pay when due any Loan Fee
payable to Lender pursuant to this Agreement, interest on the Loan, expenses
of Lender which are Borrower's responsibility under this Agreement, and
such other sums as may be payable from time to time by Borrower to Lender
with respect to the Loan. Such payments at the option of Lender may be made
by debiting or charging the Funds in the amount of such payments without
first disbursing such amounts to Borrower. In addition, Borrower hereby
authorizes Lender, at its option, to make such other payments as Lender deems
necessary or desirable to maintain the validity and priority of the Deed of
Trust, including the following, unless Borrower makes the payment within
ten (10) days after written notice from Lender:
(a) pay delinquent assessments and taxes on the Project:
(b) pay title insurance premiums, recording fees, and hazard,
liability and flood insurance premiums;
(c) pay contractor's liens or claims of liens against the Project,
subject to any right Borrower may have to contest such liens pursuant to
the terms of the Deed of Trust; and
(d) pay judgments affecting the Project, subject to any right
Borrower may have to contest such judgments pursuant to the terms of the
Deed of Trust.
8. REPORTING REQUIREMENTS; ADDITIONAL BORROWER COVENANTS. Throughout the
term of the Loan, Borrower, at Borrower's expense, will provide Lender with
the following:
8.1 FINANCIAL STATEMENTS: TAX RETURNS. Except as otherwise agreed in
writing by Lender, within ninety (90) days after the end of each fiscal year
of Borrower, Borrower shall provide Lender with financial statements from
Borrower showing Borrower's financial condition as of the end of the most
recent fiscal year, and within ninety (90) days after the end of each
Guarantor's fiscal year, financial statements from each Guarantor showing
his, her or its financial condition as of the end of the most recent fiscal
year. All such financial statements shall be prepared in accordance with
generally accepted accounting principles consistently applied (or such
other accounting practices as Lender may approve) and certified as correct
by the applicable person or the chief financial officer of the applicable
entity. Further, unless otherwise agreed in writing by Lender, within one
hundred twenty ( 120) days after the end of each tax year of Borrower and
each Guarantor, Borrower will provide Lender with a copy of the United
States federal income tax return filed by Borrower and each Guarantor for
his, her or its tax year most recently ended.
8.2 LEASES ETC. Borrower will provide Lender with copies of any
sale, lease, rental or other occupancy agreements entered into with respect
to all or any part of the Project, other than sales conducted in accordance
with any partial release provisions in this Agreement or any other Loan
Document or any sale which will result in the full repayment of the Loan.
Unless otherwise agreed in writing by Lender, without Lender's prior
consent, Borrower will not enter into any lease (i) on a form of lease not
previously approved by Lender, (ii) for a term of three (3) years or more,
or (iii) containing an option or right to purchase all or any part of the
Project. With respect to any lease of the whole or any part of the Project
involving an initial term of three (3) years or more, Borrower shall not,
without the prior written consent of Lender (a) permit the assignment or
subletting of all or any part of the lessee's rights under the lease unless
the right to assign or sublet is expressly reserved by the lessee under the
lease, (b) amend or modify the lease for a lesser rental
8
or term, or (c) accept surrender of the lease or terminate the lease except
in accordance with the terms of the lease.
8.3 TAXES AND ASSESSMENTS. Whenever requested by Lender, evidence
that taxes and assessments, worker's compensation insurance, and all other
bills that could result in a lien against the Project are being promptly
paid when due.
8.4 ADDITIONAL DOCUMENTS. Whenever requested by Lender, Borrower
shall promptly execute and deliver to Lender such instruments and documents
as Lender may reasonably require to further evidence the Loan or perfect or
continue the perfection of Lender's liens against and security interests in
the collateral for the Loan.
8.5 OPERATING STATEMENTS. Within fifteen (15) days following the end
of each calendar month, commencing with the first calendar month following
completion and the initial occupancy of the Project, Borrower shall provide
Lender with detailed operating statements of the Project, in a form
acceptable to Lender, showing the income and expenses for such month and the
net operating income for the Project.
8.6 RENT ROLL. Within fifteen (15) days after the end of each
calendar month, commencing with the first calendar month following
completion and the initial occupancy of the Project, Borrower shall provide
Lender with a rent roll which shall include such information as Lender may
require, including each tenant's name, the lease expiration date, the
monthly rent, and the amount of any deposits or prepaid rent Borrower is
holding.
8.7 MARKETING AND OPERATING PROJECTIONS. Within fifteen (15) days
after written request from Lender, Borrower shall provide Lender with
proforma marketing and operating projections (and updates thereto) for the
Project.
Compliance with Sections 8.5, 8.6 and 8.7 shall not be required so long
as Grantor is the occupant and operator of the business conducted on the
Project.
9. PROJECT CASH FLOW. Each month with the income and expense statement
required in Section 8.5 above, Borrower shall deposit with Lender an amount
equal to the net operating income from the Project, up to the amount of the
monthly debt service required under the Note. For purposes of this
Agreement, "net operating income" means all revenues generated by the
Project, less the actual ordinary and necessary expenses of the Project
(other than debt service on the Note), and less reserves (in amounts
reasonably acceptable to Lender) for periodic expenses (such as real property
taxes) and for working capital. Compliance with this Section 9 shall not be
required so long as Grantor is the occupant and operator of the business
conducted on the Project.
10. EVENTS OF DEFAULT; REMEDIES.
10.1 DEFAULT. Time is of the essence of this Agreement and all other
Loan Documents and the Certificate and Indemnity. Borrower will be in
default under this Agreement if (i) Borrower fails to make any payment when
due under the Note, this Agreement, any other Loan Document or the
Certificate and Indemnity; (ii) Borrower fails to perform any other covenant,
agreement or obligation to be performed by Borrower under this Agreement, any
other Loan Document or the Certificate and Indemnity; (iii) any
representation or warranty contained in this Agreement, any other Loan
Document or the Certificate and Indemnity or any financial information
furnished by Borrower or its agents to Lender in connection with the Loan
proves to be false or misleading in any material respect; (iv) there is a
material adverse change in the financial condition of Borrower or any
Guarantor which Lender in good faith believes will adversely affect
Borrower's ability to complete the Project or otherwise pay and perform all
obligations under this Agreement, any other Loan Document or the Certificate
and Indemnity; (v) Borrower defaults under the Construction Contract or any
lease or other contract or agreement relating to the construction or
operation of the Project, and such default is not cured within the
applicable cure period, if any; (vi) Borrower is in default with respect to
any other loan from Lender to Borrower; (vii) Borrower or any Guarantor
fails to pay his, her or its debts generally as they become due or files a
petition or action for relief under any bankruptcy, reorganization or
insolvency laws or makes an assignment for the benefit of creditors; (viii)
an involuntary petition is filed against Borrower or any Guarantor under
9
any bankruptcy, reorganization or other insolvency laws, or a custodian,
receiver, or trustee is appointed to take possession, custody or control of
the Project or the other properties of Borrower, or the assets of any
Guarantor, and such petition or appointment is not set aside, withdrawn or
dismissed within thirty (30) days from the date of filing or appointment; or
(ix) a stop work order is issued on any phase of the Project by a government,
judicial or legal authority with jurisdiction over the Project and the order
is not dismissed within ten (10) days after the date the order is issued.
10.2 REMEDIES. Upon the occurrence of a default, Lender may declare
the Loan to be immediately due and payable in full; make no further
disbursement of Funds, and pursue any one or more of the remedies set forth
in this Agreement or in any other Loan Document concurrently or successively
in addition to all other remedies available to Lender at law or in equity.
No remedy confirmed upon or reserved to Lender in this Agreement, any other
Loan Document or the Certificate and Indemnity, or at law or in equity, shall
be exclusive of any other remedy available to Lender, and to the extent
permitted by applicable law, all such remedies shall be cumulative and in
addition to every other remedy available to Lender.
10.3 NOTICE AND OPPORTUNITY TO CURE. Notwithstanding any other
provision of this Agreement or any other Loan Document, Lender will not
accelerate the maturity of the Loan (a) because of a monetary default under
this Agreement or any other Loan Document unless the default is not cured
within ten (10) days of the date on which Lender mails or delivers written
notice of the default to Borrower, or (b) because of a non-monetary default
under this Agreement or any other Loan Document unless the default is not
cured within thirty (30) days of the date on which Lender mails or delivers
written notice of the default to Borrower. For purposes of this Agreement,
the term "monetary default" means a failure by Borrower to make any payment
required of it pursuant to the Note or any other Loan Document, and the term
"non-monetary default" shall mean a failure by Borrower or any other person
or entity; to perform any obligation contained in this Agreement or any
other Loan Document or the Certificate and Indemnity, other than the
obligation to make payments provided for in the Note or any other Loan
Document. If a non-monetary default is capable of being cured and the cure
cannot reasonably be completed within the thirty (30) day cure period, the
cure period shall be extended up to ninety (90) days so long as Borrower has
commenced action to cure within the thirty (30) day cure period, and in
Lender's opinion, Borrower is proceeding to cure the default with due
diligence. None of the foregoing shall be construed to obligate Lender to
forbear in any other manner from exercising its remedies and Lender may
pursue any other rights or remedies which Lender may have because of a
default.
10.4 COMPLETION OF CONSTRUCTION. Upon the occurrence of a default,
Lender shall have the right, in person or through a third party designated
by Lender, to take possession of the Project and perform any and all work and
labor necessary to complete the Project. All sums expended by Lender in so
doing shall be deemed to have been advanced under the Note and secured by the
Deed of Trust and the other Loan Documents. Any Funds disbursed by Lender in
excess of the maximum principal amount of the Loan will be considered an
additional loan to Borrower, bearing interest at the interest rates provided
for in the Note, and secured by the Deed of Trust and all other Loan
Documents. Lender, by electing to so complete the Project will not be deemed
to have assumed any liability to Borrower or any other person or entity for
completing the Project or for the manner or quality of construction of the
Project, and Borrower hereby expressly waives any such liability on behalf of
Lender. Borrower hereby constitutes and appoints Lender as its true and
lawful attorney in fact with full power of substitution to complete the
Project in the name of Borrower and to (a) use any Funds for the purpose of
completing the Project; (b) make such additions, changes and corrections in
the Plans and Specifications or the Project Budget as Lender deems desirable;
(c) employ contractors, subcontractors, architects and other persons as
shall be required for such purposes; (d) pay, settle or compromise all
existing bills and claims which may be liens against the Project or as may be
necessary or desirable for the completion of the Project or for clearance of
title; and (e) do any and all things which Borrower might do on its own
behalf in order to complete the Project free and clear of all liens and
encumbrances. The power of attorney granted pursuant to this paragraph shall
be deemed a power coupled with an interest and irrevocable.
11 . SECURITY INTEREST - BORROWER FUNDS; OFFSETS. Borrower hereby grants
Lender a security interest in all of Borrower's right, title and interest,
if any, in the undisbursed Loan proceeds and in all other monies of Borrower
of every kind and nature which are or will be on deposit with Lender, whether
in the Loan Account or otherwise. Following a default, Lender may
10
apply any Funds in Lender's possession or under Lender's control at any time
in satisfaction of Borrower's obligations to Lender under the Loan Documents
or the Certificate and Indemnity, without notice to Borrower. Furthermore,
following a default, Lender may apply to any obligation of Borrower under
this Agreement, or other Loan Document or the Certificate and Indemnity, or
under any other agreement or on any other account, any funds of Borrower
which are in Lender's possession or control at any time, including the
proceeds of the Loan or any other loan Borrower may now have or hereafter
have in process with Lender.
12. UNAUTHORIZED LIENS AND ENCUMBRANCES.
12.1 NO LIENS OR ENCUMBRANCES. No equipment, materials, fixtures or
any other part of the Improvements shall be purchased or installed under
conditional sales agreements or other arrangements where a right is reserved
or may accrue to anyone to remove or repossess such items. Borrower will
keep the Project free and clear of all liens and claims of any kind, whether
or not superior to the Deed of Trust, except for permitted exceptions set
forth in the Title Policy or otherwise approved in writing by Lender.
12.2 LIEN CLAIMS. If any lien or claim of lien is filed against the
Project, or if a notice of intent to file such a lien is received by Lender,
or if a judgment or other encumbrance is placed against the Project, at
Lender's option, such event shall constitute a default under this Agreement
unless Borrower obtains a release and satisfaction of such lien, claim of
lien, judgment or encumbrance, or provides Lender with a bond (or other
security) acceptable to Lender in the amount of one hundred fifty percent
(150%), or such other amount as Lender may require in writing, of the lien,
claim of lien, judgment or encumbrance within twenty (20) days of written
notice by Lender to Borrower of the existence of such claim, lien or
encumbrance; however, in lieu of posting such bond (or other security)
Borrower may provide Lender with affirmative title insurance coverage from
the issuer of the Title Policy, in form and content acceptable to Lender,
with regards to the lien, claim, judgment or encumbrance. In addition,
Lender, at its option, may withhold from the Funds such amount as may be
required by applicable law, or sufficient, in Lender's opinion, to pay the
full amount of the lien, claim, judgment or other encumbrance, plus any
related interest, attorneys' fees and costs, whichever is greater. Lender's
rights under this paragraph shall not be affected by any claim by Borrower
that the claim, lien, judgment or encumbrance is invalid, it being understood
that the decision of Lender to pay or withhold shall be made by Lender in
its reasonable discretion, subject only to Borrower's right to provide a
bond or other security satisfactory to Lender as provided above.
13. NO THIRD PARTY RIGHTS; ASSIGNMENT. This Agreement is made entirely
for the benefit of Borrower, Lender and Lender's successor's in interest,
and no third person shall have any rights under this Agreement whatsoever.
Neither this Agreement or the proceeds of the Loan shall be assignable by
Borrower without Lender's prior written consent, which consent may be
withheld by Lender in its sole discretion. Any attempted assignment by
Borrower without Lender's consent shall be void. Borrower acknowledges it
shall have no right, title or interest in and to any of the Loan proceeds
until such time as such Funds have been disbursed by Lender in accordance
with this Agreement. Lender and its successors and assigns may assign the
whole or any part of the Loan or this Agreement or have other financial
institutions participate in the Loan. Each assignee or participating
institution shall be entitled to all of the rights and benefits of Lender
under this Agreement, all other Loan Documents and the Certificate and
Indemnity.
14. MISCELLANEOUS.
14.1 SIGNS AND ADVERTISING. Until the Project is completed and the
Loan is paid in full, Lender may place a sign on the Project indicating
Lender is providing the construction financing for the Project. In addition,
Lender may publicize the financing and may indicate on such signs and
publicity releases the name of Borrower and a general description of the
Project.
14.2 COSTS AND EXPENSES. Whether or not suit is brought, Borrower
shall pay on demand all costs and expenses, including attorneys' fees and
costs and allocated costs of in-house legal counsel, incurred by or on behalf
of Lender in connection with the Loan, including without limitation costs
incurred in collection of the Loan, in protecting the security for the Loan,
in foreclosing, enforcing or interpreting this Agreement, the Note, any other
Loan Document or the Certificate and Indemnity, or resulting from Lender
being made a party to any litigation because of
11
the existence of the Deed of Trust, any other Loan Document or the
Certificate and Indemnity Without limiting the generality of the foregoing,
if Borrower becomes the subject of any bankruptcy or insolvency proceeding,
Borrower shall pay all fees and expenses incurred by Lender in connection
with such bankruptcy or insolvency proceeding. Lender also shall have the
right to commence an action or appear in any proceeding or action affecting
the Project, the rights and duties of the parties hereunder, or the payment
of funds pursuant to this Agreement. Lender shall have the right to incur
expenses, employ counsel and pay legal fees (including the allocated costs of
in-house counsel) and to charge the Loan account or any other funds on
deposit with Lender by Borrower. In addition to the foregoing, Borrower
shall pay all fees, expenses and charges of Lender with respect to the Loan,
including any costs or expenses incurred by Lender in connection with the
satisfaction of any pressing or funding conditions, such as credit report
services, appraisal and internal appraisal review fees, title insurance
charges and other "out-of-pocket" expenses of Lender, regardless of whether
the Loan is closed, including charges of outside legal counsel and/or
allocated costs of in-house legal counsel.
14.3 NOTICES. Any notice given pursuant to this Agreement shall be
in writing and shall be personally delivered or mailed. If mailed, a notice
shall be sent certified mail, return receipt requested, postage prepaid and
shall be deemed to be received on the date of delivery or the third (3rd)
business day following the date of mailing, whichever shall first occur. Any
notice to Borrower shall be mailed or delivered to the address of the
"Grantor" specified in the Deed of Trust or such other address as Borrower
may from time to time specify in writing, and any notice to Lender shall be
mailed or delivered to the address of the "Beneficiary" specified in the Deed
of Trust or such other address as Lender may from time to time specify in
writing.
14.4 APPLICABLE LAW. This Agreement shall be governed by and
construed in accordance with the laws of the State of Washington. This
Agreement is the result of substantial negotiations between Borrower and
Lender and shall be construed in accordance with the fair intent and meaning
of the language contained in this Agreement in its entirety and not for or
against either party, regardless of which party (or its legal counsel) was
responsible for its preparation. Borrower and Lender each represent to the
other that each has consulted with its own legal counsel in connection with
this Agreement.
14.5 NONWAIVER. The failure of Lender to insist upon strict
performance of a covenant for obligation of Borrower under this Agreement
shall not be deemed a waiver of Lender's right to demand strict compliance
therewith in the future, nor will a periodic advance of Funds by Lender
waive any condition to advance not fulfilled at the time of the advance.
14.6 MODIFICATION. No modification, amendment or waiver of any term
or condition of this Agreement or any other Loan Document or the Certificate
and Indemnity shall be effective unless set forth in writing and signed by
Lender and Borrower.
14.7 COUNTERPARTS. This Agreement, any other Loan Document or the
Certificate and Indemnity may be executed in any number of counterparts,
each of which shall be deemed an original, but all of which together shall
constitute one and the same instrument.
DATED as of the day and year first written above.
NOTICE: ORAL AGREEMENTS OR ORAL COMMITMENTS TO LOAN MONEYs EXTEND CREDIT OR
TO FOREBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT ENFORCEABLE UNDER
WASHINGTON LAW.
LENDER: BORROWER:
SEATTLE-FIRST NATIONAL BANK, THE COEUR D'ALENES COMPANY,
a national banking association an Idaho corporation
By: By: /s/Xxxxxxx Xxxxxxxxx
---------------------------- ----------------------------
Its: Its: Treasurer
--------------------------- --------------------------
12
CONSTRUCTION LOAN AGREEMENT BETWEEN
SEATTLE-FIRST NATIONAL BANK, AS LENDER, AND
THE COEUR D'ALENES COMPANY,
AN IDAHO CORPORATION, AS BORROWER
INDEX
PAGE
RECITALS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . -1-
AGREEMENT . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . -1-
1. LOAN . . . . . . . . . . . . . . . . . . . . . . . . . . . -1-
2. LOAN DOCUMENTS . . . . . . . . . . . . . . . . . . . . . . -1-
2.1 DEED OF TRUST . . . . . . . . . . . . . . . . . . -1-
2.2 FINANCING STATEMENTS . . . . . . . . . . . . . . . -1-
2.3 GUARANTEES . . . . . . . . . . . . . . . . . . . . -2-
2.4 ASSIGNMENT OF CONSTRUCTION CONTRACT ARCHITECT'S
CONTRACT AND PLANS AND SPECIFICATIONS . . . . . . -2-
3. LOAN FEE . . . . . . . . . . . . . . . . . . . . . . . . . -2-
4. PRE-CLOSING REQUIREMENTS . . . . . . . . . . . . . . . . . -2-
4.1 LOAN DOCUMENTS . . . . . . . . . . . . . . . . . . -2-
4.2 LOAN FEE . . . . . . . . . . . . . . . . . . . . . -2-
4.3 CERTIFICATE AND INDEMNITY . . . . . . . . . . . . -2-
4.4 TITLE INSURANCE . . . . . . . . . . . . . . . . . -2-
4.5 UCC SEARCHES . . . . . . . . . . . . . . . . . . . -2-
4.6 FINANCIAL CONDITION . . . . . . . . . . . . . . . -3-
4.7 CONSTRUCTION MATTERS . . . . . . . . . . . . . . . -3-
4.8 PERMITS . . . . . . . . . . . . . . . . . . . . . -3-
4.9 LITIGATION . . . . . . . . . . . . . . . . . . . . -3-
4.10 OTHER CONDITIONS . . . . . . . . . . . . . . . . . -3-
5. CONSTRUCTION COVENANTS . . . . . . . . . . . . . . . . . . . -3-
5.1 PLANS AND SPECIFICATIONS; PROJECT BUDGET . . . . . -3-
5.2 COMPLETION OF PROJECT . . . . . . . . . . . . . . -3-
5.3 COMMENCEMENT AND COMPLETION . . . . . . . . . . . -3-
5.4 CHANGES IN PLANS AND SPECIFICATIONS, CHANGE
ORDERS . . . . . . . . . . . . . . . . . . . . . . -4-
5.5 ABANDONMENT OF CONSTRUCTION . . . . . . . . . . . -4-
6. EQUITY . . . . . . . . . . . . . . . . . . . . . . . . . . . -4-
7. DISBURSEMENTS . . . . . . . . . . . . . . . . . . . . . . . -4-
7.1 GENERAL CONDITIONS TO DISBURSEMENTS . . . . . . . -5-
7.2 DISBURSEMENTS FOR CONSTRUCTION COSTS . . . . . . . -5-
7.3 DISBURSEMENTS FOR OTHER COSTS . . . . . . . . . . -6-
7.4 INSPECTIONS BY LENDER . . . . . . . . . . . . . . -6-
7.5 AMOUNT OF DISBURSEMENTS . . . . . . . . . . . . . -7-
7.6 LOAN BALANCING . . . . . . . . . . . . . . . . . . -7-
7.7 USE AND APPLICATION OF FUNDS . . . . . . . . . . . -7-
7.8 FINAL DISBURSEMENT . . . . . . . . . . . . . . . . -7-
7.9 EXPENSES, FEES AND INTEREST . . . . . . . . . . . -8-
8. REPORTING REQUIREMENTS; ADDITIONAL
BORROWER COVENANTS . . . . . . . . . . . . . . . . . . . . . -8-
8.1 FINANCIAL STATEMENTS; TAX RETURNS . . . . . . . . -8-
8.2 LEASES, ETC. . . . . . . . . . . . . . . . . . . . -8-
8.3 TAXES AND ASSESSMENTS . . . . . . . . . . . . . . -9-
8.4 ADDITIONAL DOCUMENTS . . . . . . . . . . . . . . . -9-
8.5 OPERATING STATEMENTS . . . . . . . . . . . . . . . -9-
8.6 RENT ROLL . . . . . . . . . . . . . . . . . . . . -9-
8.7 MARKETING AND OPERATING PROJECTIONS . . . . . . . -9-
9. PROJECT CASH FLOW . . . . . . . . . . . . . . . . . . . . . -9-
10. EVENTS OF DEFAULT; REMEDIES . . . . . . . . . . . . . . . . -9-
10.1 DEFAULT . . . . . . . . . . . . . . . . . . . . . -9-
10.2 REMEDIES . . . . . . . . . . . . . . . . . . . . . -10-
i
10.3 NOTICE AND OPPORTUNITY TO CURE . . . . . . . . . . -10-
10.4 COMPLETION OF CONSTRUCTION . . . . . . . . . . . . -10-
11. SECURITY INTEREST - BORROWER FUNDS; OFFSETS . . . . . . . . -10-
12. UNAUTHORIZED LIENS AND ENCUMBRANCES . . . . . . . . . . . . -11-
12.1 NO LIENS OR ENCUMBRANCES . . . . . . . . . . . . . -11-
12.2 LIEN CLAIMS . . . . . . . . . . . . . . . . . . . -11-
13. NO THIRD PARTY RIGHTS; ASSIGNMENT . . . . . . . . . . . . . -11-
14. MISCELLANEOUS . . . . . . . . . . . . . . . . . . . . . . . -11-
14.1 SIGNS AND ADVERTISING . . . . . . . . . . . . . . -11-
14.2 COSTS AND EXPENSES . . . . . . . . . . . . . . . . -11-
14.3 NOTICES . . . . . . . . . . . . . . . . . . . . . -12-
14.4 APPLICABLE LAW . . . . . . . . . . . . . . . . . . -12-
14.5 NON-WAIVER . . . . . . . . . . . . . . . . . . . . -12-
14.6 MODIFICATION . . . . . . . . . . . . . . . . . . . -12-
14.7 COUNTERPARTS . . . . . . . . . . . . . . . . . . . -12-
ii
[LOGO]
Loan No. 604938 and 453817-9
CERTIFICATE AND INDEMNITY AGREEMENT
REGARDING BUILDING LAWS AND HAZARDOUS SUBSTANCES
This Agreement is made as of December 20, 1995 by THE COEUR D'ALENES
COMPANY, an Idaho corporation ("Indemnitor"), for the benefit of
SEATTLE-FIRST NATIONAL BANK, a national banking association ("Lender"), to
induce Lender to make a loan (the "Loan") to Indemnitor in the amount of
$1,688,000.00.
In consideration of Lender agreeing to make the Loan, Indemnitor
certifies, represents, warrants, covenants and agrees as follows for the
benefit of Lender:
I . DUE lNVESTIGATION. Indemnitor has duly investigated (a) the present
and past uses of the "Property" (defined below) and has made due inquiry of
the appropriate governmental agencies and offices having jurisdiction over
the Property as to whether the Property or any "Other Property" (defined
below) is or has been the site of storage or contamination by any "Hazardous
Substances", (defined below) and Indemnitor has examined or been advised of
all "Environmental Laws" (defined below) applicable to the Property; and (b)
the condition of all buildings and other improvements on the Property and
been advised of all "Building Laws" (defined below) applicable to the
Property. Upon Lender's request, Indemnitor will provide Lender with a
written summary of its investigations and copies of all inquiries and
responses.
2. HAZARDOUS SUBSTANCES. Indemnitor has no knowledge of (a) the presence
of any Hazardous Substances on the Property or (b) any spills, releases,
discharges or disposal of Hazardous Substances that have occurred or are
presently occurring on or onto the Property or any Other Property, other than
the presence, use, storage and disposal of Hazardous Substances generally
used in the ordinary course of operating, maintaining or developing
properties such as the Property, all of which Indemnitor covenants have and
will be used, stored and disposed of in accordance with commercially
reasonable practices and all applicable Environmental Laws.
3. COMPLIANCE WITH LAWS. Indemnitor has no knowledge of (a) any failure
by any person or entity to comply with all currently applicable Environmental
Laws with respect to the generation, recycling, reuse, sale, storage
handling, transport and disposal of Hazardous Substances on or from the
Property; or (b) any failure of the Property to comply with all currently
applicable Building Laws. Indemnitor shall cause the Property to be
continuously in compliance with all Building Laws and Environmental Laws.
Indemnitor warrants the Property is the only real property or interest in
real property required to operate the Property (and all improvements thereon)
in compliance with all Building Laws, except as otherwise disclosed to Lender
in writing. All certificates of occupancy and other governmental permits and
approvals necessary for the occupancy of the property have been obtained. All
buildings and other improvements currently located on the Property are
located outside a 100-year flood plain, or are covered by adequate flood
insurance.
4. FUTURE BUILDINGS AND IMPROVEMENTS. All buildings, structures and
other improvements to be built or constructed on the Property shall be
constructed in accordance with and shall fully comply with all applicable
Building Laws and shall be located outside of any 100 year flood plain or
will be continuously covered by adequate flood insurance. With respect to all
buildings or improvements to the Property, if any, to be constructed and paid
for with Loan proceeds, Indemnitor represents and warrants no changes to the
plans and specifications for such buildings or improvements, submitted to and
approved by Lender, have been required by governmental authorities, and all
permits necessary to construct such buildings and improvements have been
issued on the basis of the plans and specifications submitted to and approved
by Lender.
-1-
5. NO RELEASE OR WAIVER. Indemnitor has not and will not release or
waive the liability of any previous owner, lessee or operator of the
Property, or any other person or entity potentially responsible under
applicable Environmental Laws for the presence or removal of Hazardous
Substances on or from the Property, and Indemnitor has made no promises of
indemnification regarding Hazardous Substances to any person or entity other
than Lender.
6. NOTICE TO LENDER. Indemnitor will immediately notify Lender if
Indemnitor receives notice or otherwise becomes aware of (a) any Hazardous
Substances or other environmental problem or liability with respect to the
Property or Other Property, (b) any lien, action or notice resulting from the
violation of any Environmental Laws or any Building Laws, or (c) the Property
being in violation of any applicable Building Law or Environmental Law. At
its own cost, Indemnitor will take all actions which are necessary or
desirable to clean up any Hazardous Substances affecting the Property,
including removal, containment or other remedial action required by
applicable law, or cause the Property to be in compliance with any applicable
Environmental Law or Building Law. Any notice sent to Lender pursuant to this
paragraph will describe with particularity any actual, potential or alleged
violation of Building Laws or Environmental Laws, and shall contain
Indemnitor's plan or recommendations for correcting the violations.
7. INDEMNIFICATION. Indemnitor shall indemnify, defend and hold Lender
harmless from and against any and all claims, demands, damages, losses,
liens, liabilities, penalties, fines, lawsuits and other proceedings and
costs and expenses (including attorneys' fees and disbursements, and
architectural, engineering and accounting costs and all repair and clean-up
costs) which accrue to or are made against or incurred by Lender, or are in
any way connected with (a) the inaccuracy of any of the certifications,
representations or warranties of Indemnitor contained in this Agreement, (b)
any activities on the Property during Indemnitor's ownership, possession or
control of the Property which directly or indirectly result in the Property
or any Other Property being contaminated with Hazardous Substances, or the
Property being in violation of any applicable Building Laws or Environmental
Laws, or (c) the discovery and/or cleanup of Hazardous Substances deposited
or existing on the Property or any Other Property, and (d) any breach by
Indemnitor of any of its covenants or agreements set forth in this Agreement.
If Lender becomes the owner of or acquires an interest in or rights to the
Property by foreclosure or by a conveyance in lieu of foreclosure of the deed
of trust (the "Deed of Trust") or any other instruments securing the Loan, or
by any other means, the foregoing indemnification obligation of Indemnitor
shall survive such foreclosure or conveyance in lieu of foreclosure or other
acquisition of the Property. Notwithstanding the preceding sentence,
Indemnitor shall have no obligation to defend, indemnify or hold Lender
harmless from any claim, demand, damage, loss, lien, liability, etc. arising
from or out of the activities of Lender or its agents on the Property on or
after transfer of the Property to Lender pursuant to foreclosure proceedings
or in lieu thereof.
8. UNCONDITIONAL AND UNSECURED OBLIGATIONS. Indemnitor's obligations
under this Agreement are unconditional and shall not be limited by any
limitations on liability provided for in any document or instrument
evidencing or securing the Loan (collectively the "Loan Documents"). The
certifications, representations, warranties, covenants and agreements of
Indemnitor set forth in this Agreement (including without limitation the
indemnity provided for in Xxxxxxxxx 0 xxxxx), (x) are separate and distinct
obligations from Indemnitor's obligations with respect to the Loan and under
the Loan Documents, (b) are not secured by the Deed of Trust or any other
Loan Document, (c) shall not be discharged or satisfied by foreclosure of the
lien of the Deed of Trust or any lien or security interest created by any
other Loan Document, and (d) shall continue in effect after any transfer of
the Property, including without limitation transfers pursuant to foreclosure
proceedings (whether judicial or nonjudicial), or by any conveyance in lieu
of foreclosure.
9. DEFINITIONS. For purposes of this Agreement:
(a) "Building Laws" means all federal, state and local laws,
statutes, regulations, ordinances and requirements, now or hereafter in
effect, applicable to the ownership, development or operation of the
Property, including all building, zoning, planning, subdivision, fire,
traffic, safety, health, labor, air quality, wetlands, shoreline and flood
plain laws, statutes, regulations, ordinances and requirements, and
specifically includes all applicable requirements of the Fair Housing Act of
-2-
1968, and the Americans With Disabilities Act of 1990, and all government and
private covenants, conditions and restrictions applicable to the Property,
all as now or hereafter amended.
(b) "Environmental Laws" means all federal, state and local statutes,
regulations, ordinances, and requirements, now or hereafter in effect,
pertaining to environmental protection, contamination or cleanup, including
without limitation (i) the Federal Water Pollution Control Act (33 U.S.C.
Section 1251 et. seq.), (ii) the Federal Resource Conservation and Recovery Act
of 1976 (42 U.S.C. Section 6901 et. seq.), (iii) the Federal Comprehensive
Environmental Response, Compensation and Liability Act of 1980 (42 U.S.C.
Section 9601 et. seq.), (iv) the Washington Model Toxics Control Act (RCW
Chapter 70.105(d)), and (v) the Washington Underground Petroleum Storage
Tanks Act (RCW Chapter 70.148), all as now or hereafter amended.
(c) "Hazardous Substances" means any chemical, substance or material
classified or designated as hazardous, toxic or radioactive, or other similar
term, and now or hereafter regulated under any Environmental Law, including
without limitation, asbestos, petroleum and hydrocarbon products.
(d) "Lender" means Seattle-First National Bank and its universal
successors and assigns, and any person or entity designated or appointed by
Lender to acquire the Property through foreclosure or by transfer in lieu of
foreclosure, and any and all other financial institutions participating in
the Loan.
(e) "Other Property" means any property which becomes contaminated
with Hazardous Substances as a result of the construction, development,
operation or other activities on, or the contamination of, the Property.
(f) "Property" means the real property situated in Spokane County,
Washington, commonly known as East 0000 Xxxxxxxx Xxxxxx, Xxxxxxx, XX 00000,
legally described in SCHEDULE A attached and all buildings, structures and
other improvements now or hereafter located thereon.
10. GENERAL. If Indemnitor is composed of more than one person or
entity, the term "Indemnitor" shall refer to each and every such person or
entity and all of such persons and entities shall be jointly and severally
liable under this Agreement. Any individual signing this Agreement does so on
his or her own behalf and on behalf of his or her marital community, unless
otherwise stated in this Agreement. This Agreement shall be binding upon and
inure to the benefit of Lender, Indemnitor and their respective heirs,
representatives, successors and assigns. This Agreement shall be governed by
and construed under the laws of the State of Washington. In any lawsuit,
action or appeal therefrom, including proceedings in bankruptcy court, to
enforce or interpret this Agreement, the prevailing party shall be entitled
to recover its costs and expenses incurred therein, including attorneys' fees
and disbursements.
DATED as of the day and year first written above.
INDEMNITOR:
THE COEUR D'ALENES COMPANY,
an Idaho corporation
By: /s/ Xxxxxxx Xxxxxxxxx
Its: Treasurer
-3-
SCHEDULE A
SCHEDULE ATTACHED TO AND FORMING PART OF THAT CERTIFICATE AND INDEMNITY
AGREEMENT REGARDING BUILDING LAWS AND HAZARDOUS SUBSTANCES DATED DECEMBER 20,
1995, GIVEN BY THE COEUR D'ALENES COMPANY, AN IDAHO CORPORATION, AS
INDEMNITOR.
------------------------------------------------------------------------------
LEGAL DESCRIPTION:
BLOCKS 000 XXX 000, XXXX XXXX SYNDICATE
ADDITION, ACCORDING TO PLAT RECORDED IN VOLUME "C" OF PLATS, PAGE 73, IN THE
CITY OF SPOKANE, SPOKANE COUNTY, WASHINGTON,
TOGETHER WITH VACATED SPRINGFIELD AVENUE ADJACENT TO SAID PREMISES.
[LETTERHEAD]
------------------------------------------------------------------------------
Loan No. 604938 and 453817-9
AGREEMENT OF SUBORDINATION
THIS AGREEMENT OF SUBORDINATION ("Agreement") is made this 20th day of
December, 1995 by and among:
"BANK" - SEATTLE-FIRST NATIONAL BANK, a national banking association
"BORROWER" - THE COEUR D'ALENES COMPANY, an Idaho corporation, and UNION IRON
WORKS, INC. OF SPOKANE WASHINGTON, a Washington corporation.
with respect to the following facts:
A. Borrower is indebted to Bank ("LOAN NO. 1") as evidenced by
Promissory Note dated March 27, 1995, in the original face amount of
$200,000.00. Payment of Loan No. I secured by, among other things, a security
interest in fixtures and personal property of Borrower (collectively the
"LOAN NO. 1 COLLATERAL") as evidenced by:
(i) Security Agreement dated March 31, 1995;
(ii) UCC Financing Statement filed March 31, 1995, under Auditor's
File No. 0000000000, and
(iii) UCC Financing Statement filed March 31, 1995, under Auditor's
File No. 9503110367.
B. Bank is making a new loan to The Coeur d'Alenes Company, an Idaho
corporation, in the principal amount of $1,688,000.00 ("LOAN NO. 2"). Payment
of Loan No. 2 will also be secured and perfected by, among other things, a
recorded Deed of Trust, Security Agreement, Fixture Filing and Assignment of
Leases and Rents, and UCC Financing Statements on some or all of the Loan No.
1 Collateral (the "LOAN NO. 2 COLLATERAL"). Bank requires as a condition of
Loan No. 2 that the Bank's lien and encumbrance on the Loan No. 2 Collateral
be a first and superior lien to the Bank's lien and encumbrance on the same
collateral securing payment of Loan No. 1.
NOW, THEREFORE, in consideration of the mutual benefits to be derived
herefrom, it is
1. RECITALS. Each of the above recitals is true and correct and,
together with the documents and agreements evidencing and securing Loan No. 1
and Loan No. 2, are incorporated herein as though fully set forth.
2. SUBORDINATION. The lien and encumbrance of Bank on the Loan No. 1
Collateral shall be subject, subordinate and inferior to the lien and
encumbrance of Bank on the Loan No. 2 Collateral, but only insofar as the
collateral for Loan No. I and Loan No. 2 is the same. Bank shall have the
right, but not the obligation, to apply the collateral to payment of Loan No.
2 prior to
-1-
payment of Loan No. 1, the Bank reserving to itself the right to apply the
collateral to Loan No. 1 and Loan No. 2 in such manner and in such order- as
Bank in its sole discretion may determine.
3. CROSS DEFAULT. Any default under Loan No. I will, at Bank's option be
a default on Loan No. 2, and any default on Loan No. 2 will, at Bank's
option, be a default on Loan No. 1.
4. NO OTHER ENCUMBRANCE. Borrower and each of them represents and
warrants to Bank that except for (i) the encumbrance and security interest of
Bank, (ii) the lien of real estate taxes and assessments not yet due, (iii)
tenants in the possession under leases approved by Bank or subordinate to
Bank's encumbrance and security interest, and (iv) other exceptions to title
approved in writing by Bank, there exists no lien, charge or encumbrance
against any of the Loan No. l Collateral or Loan No. 2 Collateral.
5. GOVERNING LAW. This Agreement shall be construed and enforced under
the laws of the State of Washington. In any action or proceeding to construe
or enforce this Agreement, the prevailing party shall recover its costs and
reasonable attorneys' fees including those incurred in any trial or
arbitration proceeding, in any bankruptcy or receivership proceeding, and in
any appeal therefrom.
NOTICE: ORAL AGREEMENTS, PROMISES OR COMMITMENTS TO: (1) LOAN MONEY, (2) EXTEND
CREDIT, (3) MODIFY OR AMEND ANY TERMS OF THE LOAN DOCUMENTS, (4) RELEASE ANY
GUARANTOR, (5) FORBEAR FROM ENFORCING REPAYMENT OF THE LOAN OR THE EXERCISE OF
ANY REMEDY UNDER THE LOAN DOCUMENTS, OR (6) MAKE ANY OTHER FINANCIAL
ACCOMMODATION PERTAINING TO THE LOAN ARE ALL UNENFORCEABLE UNDER WASHINGTON LAW.
Made to be effective as of the date first so
BANK:
SEATTLE-FIRST NATIONAL BANK,
a national banking association
By:
---------------------------
Its:
--------------------------
BORROWER:
THE COEUR D'ALENES COMPANY,
an Idaho corporation
By: /S/ Xxxxxxx Xxxxxxxxx
--------------------------
Its: Treasurer
-------------------------
UNION IRON WORKS, INC. OF SPOKANE, WASHINGTON
a Washington corporation
By: /S/ Xxxxxxx Xxxxxxxxx
---------------------------
Its: Treasurer
-------------------------
-2-
STATE OF WASHINGTON )
)SUBSECTION
COUNTY OF _________ )
On this day personally appeared before me _________________ to me known
(or proven on the basis of satisfactory evidence) to be the _________ of
SEATTLE FIRST NATIONAL BANK, a national banking association, the corporation
that executed the within and foregoing instrument, and acknowledged said
instrument to be the free and voluntary act and deed of said corporation, for
the uses and purposes therein mentioned, and on oath stated that _he was
authorized to execute said instrument.
GIVEN UNDER my hand and official seal this ___ day of ____________, ____.
________________________________________________
(Print Notary Name)_____________________________
Notary Public in and for the State of Washington
residing at ____________________________________
My appointment expires _________________________
STATE OF WASHINGTON )
)SUBSECTION
COUNTY OF SPOKANE )
On this day personally appeared before me Xxxxxxx Xxxxxxxxx to me known
(or proven on the basis of satisfactory evidence) to be the Treasurer of THE
COEUR D'ALENES COMPANY, an Idaho corporation, the corporation that executed
the within and foregoing instrument, and acknowledged said instrument to be
the free and voluntary act and deed of said corporation, for the uses and
purposes therein mentioned, and on oath stated that _he was authorized to
execute said instrument.
GIVEN UNDER my hand and official seal this 5th day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
------------------------------------------------
XXXXXXXX X. XXXXXX
Notary Public in and for the State of Washington
residing at Greenacres WA
My appointment expires 0-00-00
XXXXX XX XXXXXXXXXX )
)SUBSECTION
COUNTY OF SPOKANE )
On this day personally appeared before me Xxxxxxx Xxxxxxxxx to me known
(or proven on the basis of satisfactory evidence) to be the Treasurer of
UNION IRON WORKS, INC. OF SPOKANE, WASHINGTON, a Washington corporation, the
corporation that executed the within and foregoing instrument, and
acknowledged said instrument to be the free and voluntary act and deed of
said corporation, for the uses and purposes therein mentioned, and on oath
stated that _he was authorized to execute said instrument.
GIVEN UNDER my hand and official seal this 5th day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
------------------------------------------------
XXXXXXXX X. XXXXXX
Notary Public in and for the State of Washington
residing at Greenacres WA
My appointment expires 8-27-99
-3-
(Letterhead)
Loan No. 604938 and 453817-9
LOAN MODIFICATION AND ADDITIONAL ADVANCE AGREEMENT
THIS LOAN MODIFICATION AND ADDITIONAL ADVANCE AGREEMENT ("Agreement") is made to
be effective as of November 12, 1996, by and between:
"LENDER" - BANK OF AMERICA NW, N.A., doing business as SEAFIRST BANK,
successor by name change to Seattle-First National Bank
"BORROWER" - THE COEUR D'ALENES COMPANY, an Idaho corporation
with respect to the following facts:
A. On or about December 20, 1995, Lender loaned to Borrower the
principal sum of $1,688,000.00 (the "LOAN"), which Loan is evidenced by a
Promissory Note ("NOTE") and secured by a Deed of Trust ("DEED OF TRUST") made
by Borrower as Grantor, recorded February 8, 1996, in Spokane County,
Washington, under recording numbers 9602080190, 0000000000, 9602080192 and
9602080193, and constituting a first lien encumbrance on the real and personal
property and fixtures (the "PROPERTY") described in the Deed of Trust or in any
UCC financing statement filed with respect thereto. The loan documents described
in this paragraph and other documents evidencing and securing the Loan are
collectively described as the "LOAN DOCUMENTS."
B. Borrower and Lender desire to modify and increase the Loan as
provided in and subject to the terms and conditions of this Agreement.
NOW, THEREFORE, in consideration of the mutual benefits to be derived
herefrom, it is agreed:
1. RECITALS. The above recitals are true and correct and together with
the Loan Documents, are by this reference incorporated into this Agreement as
though fully set forth.
2. MODIFICATION OF LOAN DOCUMENTS. Lender and Borrower agree that the
Loan and Loan Documents shall be modified as follows:
a. RESTATED NOTE. Borrower shall execute and deliver to Lender, in
the form required by Lender, an Amended and Restated Promissory Note ("RESTATED
NOTE") which will replace and supersede the Note. The Restated Note will include
an additional principal advance of $262,000.00 ("ADDITIONAL ADVANCE").
References in the Loan Documents to the Note shall mean the Restated Note. The
Restated Note will be secured by the Deed of Trust. Funding of the undisbursed
balance of the Restated Note will be subject to the terms and conditions of the
Construction Loan Agreement dated December 20, 1995 between Borrower and Lender.
b. CONSTRUCTION LOAN AGREEMENT. The Loan Fee to convert to a permanent
loan in accordance with the terms of the Note is increased from $8,440.00 to
$9,750.00.
c. AMENDMENT TO OTHER DOCUMENTS. Borrower agrees to sign and deliver
or cause to be signed and delivered to Lender such other documents as Lender
may require to complete the modifications to the loan described herein.
3. REPRESENTATIONS AND WARRANTIES. To induce Lender to enter into this
Agreement, Borrower represents and warrants:
1
a. Borrower has full legal power and authority to enter into this
Agreement, that all necessary consents and approvals for the execution and
performance of this Agreement have been obtained, and when signed and
delivered to Lender this Agreement will be the legal binding and enforceable
obligation of Borrower.
b. Borrower owns and is vested in title to all of the Property
described in the Deed of Trust or otherwise securing payment of the Loan and,
except for the lien of real estate taxes and assessments not yet due, tenants
in possession under leases approved by Lender or which are subordinate to the
Deed of Trust, and other exceptions to title approved in writing by Lender,
there exists no lien, charge or encumbrance against the Property created or
arising subsequent to the recording date of the Deed of Trust.
c. The, unpaid principal balance of the Loan as of the effective
date of this Agreement is $1,678,728.00 and Borrower has no defense, claim or
setoff, legal or equitable, to the full payment and performance of Borrower's
obligations to Lender under the Loan Documents as herein modified.
d. Borrower acknowledges that Borrower has read this Agreement and
all other documents required by Lender in connection with this Agreement, is
familiar with their respective terms and conditions, and has had the
opportunity for advice of counsel of Borrower's own selection in regard to
the terms, meaning and effect of this Agreement and all such other documents.
Borrower further acknowledges that Borrower has made this Agreement freely
and voluntarily, without duress, and in reliance on no promise or
representation of Lender or by which Lender is bound not expressly set forth
herein.
4. CONDITIONS. Lender's agreement to modify the Loan as provided herein
is subject to satisfaction of each of the following conditions by not later
than November 26, 1996, time being of the essence. Each condition is for the
exclusive benefit of Lender and may be waived by Lender but any waiver must be
in writing and signed by Lender in order to be effective.
a. There is no uncured event of default under the Loan, nor any
event or condition which, with notice or the passage of time or both, would be
an event of default under the Loan.
b. Datedown, additional advance and/or mortgage modification
endorsements, in form satisfactory to Lender, shall have been added to
Lender's loan policy of title insurance ("LOAN POLICY") for the Deed of Trust,
bringing the effective date of the Loan Policy current to the effective date
of this Agreement and insuring that the modifications provided for herein
shall not impair the continued validity, priority and enforceability of the
Deed of Trust.
c. This Agreement and all other documents and agreements required by
Lender have been fully signed, acknowledged and delivered to Lender and, if
required by Lender, filed of record.
d. Satisfaction of all other conditions and requirements to
modification of the Loan, if any, as may be contained in a letter, exhibit
list or other written communication by Lender to Borrower.
5. RELEASE. As additional consideration for the modification of the Loan
as herein set forth, Borrower does hereby release and forever discharge
Lender, every participant in the Loan, and each and every of their respective
employees, agents, directors, officers, subsidiaries, parent corporations and
affiliates (collectively the "RELEASED PARTIES"), of and from all damage,
loss, claims, demands, liabilities, obligations, actions and causes of action
whatsoever which Borrower may have or claim to have against the Released
Parties or any of them as of the effective date of this Agreement, whether
presently known or unknown, on account of or in any way concerning, arising
out of or founded upon the Loan including, but not limited to, all such loss
or damage of any kind heretofore sustained, or that may arise as a consequence
of the dealings between the parties up to and including the effective date of
this Agreement. This release and the covenants herein on the part of Borrower
are contractual and not a mere recital, and the parties agree that no
liability is admitted except Borrower's indebtedness to Lender under the Loan
Documents and that all agreements and
2
understandings between Borrower and Lender concerning the Loan are expressed
and embodied in the Loan Documents, as modified hereby.
6. GENERAL.
a. ENTIRE AGREEMENT. This Agreement constitutes the entire agreement
between Borrower and Lender with respect to the foregoing modification of the
Loan and shall not be amended except in writing signed by Lender and Borrower.
b. RATIFICATION. As modified herein the Loan Documents are ratified
and affirmed and shall be and remain in full force and effect. Borrower shall
promptly pay and perform as and when due all of Borrower's obligations under
the Loan Documents and this Agreement. This Agreement is not intended to and
shall not be construed to impair the validity, priority or enforceability of
the Deed of Trust or the other Loan Documents.
c. CROSS-DEFAULT. Any default by Borrower under this Agreement shall
constitute a default under the Loan Documents, and each of them, and any
default by Borrower under any Loan Document shall constitute a default under
this Agreement.
d. LENDER'S EXPENSES. Borrower shall pay all costs and expenses of
Lender incurred in connection herewith including, without limitation, credit
report fees, appraisal and internal appraisal review fees, title insurance
charges, escrow and recording fees, document preparation charges, and charges
of outside legal counsel and allocated cost of in-house legal counsel.
e. GOVERNING LAW. This Agreement shall be construed and enforced
under the laws of the State of Washington. In any action or proceeding to
construe or enforce this Agreement or any of the Loan Documents, the
prevailing party shall recover its costs an reasonable attorneys' fees
including those incurred in any trial or arbitration proceeding, in any
bankruptcy or receivership proceeding, and in any appeal therefrom.
NOTICE: ORAL AGREEMENTS, PROMISES OR COMMITMENTS TO: (1) LOAN MONEY, (2)
EXTEND CREDIT, (3) MODIFY OR AMEND ANY TERMS OF THE LOAN DOCUMENTS, (4)
RELEASE ANY GUARANTOR, (5) FORBEAR FROM ENFORCING REPAYMENT OF THE LOAN OR THE
EXERCISE OF ANY REMEDY UNDER THE LOAN DOCUMENTS, OR (6) MAKE ANY OTHER
FINANCIAL ACCOMMODATION PERTAINING TO THE LOAN ARE ALL UNENFORCEABLE UNDER
WASHINGTON LAW.
Made to be effective as of the date first set forth above.
LENDER:
SEAFIRST BANK
By: ----------------------
Its: ---------------------
BORROWER:
THE COEUR D'ALENES COMPANY,
an Idaho corporation
By: /s/ Xxxxxxx Xxxxxxxxx
----------------------
Its: Treasurer
---------------------
3
CONSENT OF SUBORDINATORS:
A. THE HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE
OCTOBER 31, 1998 hereby consent to the loan modification and additional advance
made by this Agreement, and do hereby ratify and affirm as continuing and in
full force and effect that certain Subordination Agreement, dated February 5,
1996, recorded February 8, 1996 under Spokane County Recording No. 9602080195.
THE HOLDERS OF THE COEUR D'ALENES
COMPANY'S CONVERTIBLE DEBENTURES
DUE OCTOBER 31, 1998
BY: /s/CINV, X.X. XXXXXXX
---------------------
ITS: GENERAL PARTNER
---------------------
BY: /s/XXXXXX X. XXXXXXXXX
---------------------
ITS: BENEFICIARY
---------------------
BY: /s/XXXXX X. XXXX
---------------------
ITS:
---------------------
BY: /s/XXXX XXXX
---------------------
ITS:
---------------------
BY: /s/XXX XXXXXX
---------------------
ITS:
---------------------
BY: /s/XXXXXXX X. XXXXXX
---------------------
ITS:
---------------------
B. UNION IRON WORKS, INC., OF SPOKANE WASHINGTON hereby consents to the loan
modification and additional advance made by this Agreement, and does hereby
ratify and affirm as continuing and in full force and effect that certain
Agreement of Subordination, dated December 20, 1995, recorded February 8, 1996
under Spokane County Recording No. 9602080194.
By: /s/ XXXXXXX XXXXXXXXX
---------------------
Its: Treasurer
---------------------
4
STATE OF WASHINGTON )
)Section
COUNTY OF ___________ )
On this day personally appeared before me _______________________, to me
known (or proven on the basis of satisfactory evidence) to be the
_______________ of BANK OF AMERICA NW, N.A., the corporation that executed
the within and foregoing instrument, and acknowledged said instrument to be
the free and voluntary act and deed of said corporation, for the uses and
purposes therein mentioned, and on oath stated that he was authorized to
execute said instrument.
GIVEN UNDER my hand and official seal this ___ day of _____________,1996.
_________________________________________
(Print Notary Name)______________________
Notary Public in and for the State of
Washington residing at __________________
My appointment expires___________________
STATE OF WASHINGTON )
)Section
COUNTY OF Spokane )
On this day personally appeared before me Xxxxxxx Xxxxxxxxx to me known
(or proven on the basis of satisfactory evidence) to be the Treasurer of THE
COEUR D'ALENES COMPANY, an Idaho corporation, the corporation that executed
the within and foregoing instrument, and acknowledged said instrument to be
the free and voluntary act and deed of said corporation, for the uses and
purposes therein mentioned, and on oath stated that she was authorized to
execute said instrument.
GIVEN UNDER my hand and official seal this 27 day of November 1996.
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 0-0-0000
XXXXX XX XXXXXXXXXX )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that L.A . Xxxxxxx,
is the person who appeared before me, and said person acknowledged that he
signed this instrument on oath stated that he was authorized to execute the
instrument and acknowledge it as the General Partner of THE HOLDERS OF THE
COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER 31, 1998, to be
the free and voluntary act of such party for the uses and purposes mentioned
in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 9-6-2000
5
STATE OF WASHINGTON )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxxxxx X.
Xxxxxxxxx, is the person who appeared before me, and said person acknowledged
that he signed this instrument on oath stated that he was authorized to
execute the instrument and acknowledge it as the General Partner of THE
HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER
31, 1998, to be the free and voluntary act of such party for the uses and
purposes mentioned in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 0-0-0000
XXXXX XX XXXXXXXXXX )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxxxx X. Xxxx,
is the person who appeared before me, and said person acknowledged that _he
signed this instrument on oath stated that he was authorized to execute the
instrument and acknowledge it as the General Partner of THE HOLDERS OF THE
COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER 31, 1998, to be
the free and voluntary act of such party for the uses and purposes mentioned
in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 0-0-0000
XXXXX XX XXXXXXXXXX )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxxx Xxxx, is
the person who appeared before me, and said person acknowledged that she
signed this instrument on oath stated that she was authorized to execute the
instrument and acknowledge it as the General Partner of THE HOLDERS OF THE
COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER 31, 1998, to be
the free and voluntary act of such party for the uses and purposes mentioned
in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 9-6-2000
6
STATE OF WASHINGTON )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxx Xxxxxx, is
the person who appeared before me, and said person acknowledged that he
signed this instrument on oath stated that he was authorized to execute the
instrument and acknowledge it as the General Partner of THE HOLDERS OF THE
COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER 31, 1998, to be
the free and voluntary act of such party for the uses and purposes mentioned
in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 0-0-0000
XXXXX XX XXXXXXXXXX )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxxxxxx X.
Xxxxxx, is the person who appeared before me, and said person acknowledged
that she signed this instrument on oath stated that she was authorized to
execute the instrument and acknowledge it as the General Partner of THE
HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER
31, 1998, to be the free and voluntary act of such party for the uses and
purposes mentioned in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 0-0-0000
XXXXX XX XXXXXXXXXX )
)Section
COUNTY OF Spokane )
I certify that I know or have satisfactory evidence that Xxxxxxx
Xxxxxxxxx, is the person who appeared before me, and said person acknowledged
that she signed this instrument on oath stated that she was authorized to
execute the instrument and acknowledge it as the General Partner of THE
HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER
31, 1998, to be the free and voluntary act of such party for the uses and
purposes mentioned in the instrument.
Dated: 27 November 1996
Xxxxxxx X. Xxxxxxxxxx
(Print Notary Name) Xxxxxxx X. Xxxxxxxxxx
Notary Public in and for the State of
Washington residing at Spokane
My appointment expires 9-6-2000
7
[LOGO]
Loan No. 604938 and 453817-9
FIRST AMENDED AND RESTATED
PROMISSORY NOTE
$1,950,000.00 November 12, 0000
Xxxxxxx, Xxxxxxxxxx
THIS FIRST AMENDED AND RESTATED PROMISSORY NOTE ("NOTE") IS THE 'RESTATED
NOTE' REFERRED TO IN THE LOAN MODIFICATION AND ADDITIONAL ADVANCE AGREEMENT
OF EVEN DATE HEREWITH BETWEEN MAKER AND LENDER. THIS NOTE SUPERSEDES AND
REPLACES IN ITS ENTIRETY BUT DOES NOT CONSTITUTE A NOVATION OF THAT CERTAIN
NOTE DATED DECEMBER 20, 1995, BY MAKER AND PAYABLE TO LENDER IN THE FACE
AMOUNT OF $1,688,000.00. THIS NOTE CONTAINS MODIFICATIONS AND CHANGES IN THE
TERMS OF THE LOAN BY LENDER TO MAKER.
FOR VALUE RECEIVED, the undersigned ("MAKER") promise(s) to pay to the
order of BANK OF AMERICA NW, N.A., doing business as SEA FIRST BANK
("LENDER"), at its principal office in Seattle, Washington, or at such other
place or places or to such other party as the "HOLDER" (defined below) may
from time to time designate in writing, the principal sum of ONE MILLION NINE
HUNDRED FIFTY THOUSAND AND NO/100 DOLLARS ($1,950,000.00), or so much thereof
as may be advanced, in lawful money of the United States of America, together
with interest thereon, on the following agreements, terms and conditions. The
term "HOLDER" as used in this Note means Lender or any future holder of this
Note, and their successors and assigns.
1. TERM. This Note shall have an initial term (the "CONSTRUCTION
TERM") expiring on January 1, 1997. The last day of the Construction Term is
referred to in this Note as the "MATURITY DATE". If Maker is not then in
default under this Note or any other documents or instruments executed by
Maker in connection with the loan (the "LOAN") evidenced by this Note
(collectively with this Note, the "LOAN DOCUMENTS"), on or before the last
day of the Construction Term, the Loan shall convert to a permanent loan (the
"PERMANENT LOAN") if Maker has complied with the following conditions, and
with all other conditions as may be specified in any other Loan Document:
(a) Maker shall have provided the Holder with current financial
statements of Maker, any general partner in Maker and any guarantor of the
Loan, each certified as correct by the appropriate party, showing no material
adverse change in any such person's or entity's financial condition from the
date of this Note, and otherwise acceptable to the Holder in its sole
discretion;
(b) Maker is not then in default under this Note or any other loan
Document;
(c) The improvements to be constructed with the proceeds of the
Loan shall have been completed in accordance with the plans and
specifications for the improvements approved by Lender and a certificate of
occupancy shall have been issued by the applicable governmental authority
allowing the use and occupancy of the improvements for their intended
purposes; and
(d) Maker shall have complied with such other conditions to the
conversion as the Holder may reasonably require and specify in writing prior
to the date of the conversion.
If the Loan is converted to the Permanent Loan as provided above, the
Maturity Date shall be extended to that date which is one hundred twenty
(120) months from the first day of the first calendar month following the
date of the conversion unless otherwise agreed in writing by the Holder.
1
2. INTEREST. Interest shall commence to run on each advance under this
Note from the date of the advance and will be computed on the outstanding
balance of this Note as it exists from time to time at the interest rates
provided for in subparagraphs 2(a) and 2(b) below, as applicable. After
maturity, or after default, interest shall accrue on the outstanding
principal balance of this Note at an interest rate equal to four percentage
points (4%) per annum above the interest rate otherwise applicable to this
Note.
(a) CONSTRUCTION TERM INTEREST. During the Construction Term, the
principal balance of this Note shall bear interest at a per annum interest
rate equal to the sum of the publicly announced prime rate (the "PRIME RATE")
of Lender, as the same may change from time to time, plus three hundred
twenty-five one thousandths of one percentage point (0.325%) per annum.
Interest rate adjustments caused by changes to the Prime Rate shall be
effective the same day as the adjustments to the Prime Rate are effective.
Interest on this Note during the Construction Term shall be computed on the
basis of a 360-day year and the actual number of days elapsed in the period
for which interest is payable.
(b) PERMANENT LOAN INTEREST. If the Loan converts to the Permanent
Loan, interest shall accrue on the principal balance of this Note either at a
variable interest rate as provided in subparagraph 2(b)(i) below (the
"VARIABLE RATE"), or at a fixed interest rate as provided in subparagraph
2(b)(ii) below (the "FIXED RATE"). After conversion to the Permanent Loan,
interest on this Note shall be calculated A 30-day month and a 360-day year.
(i) VARIABLE RATE. Unless Maker elects to have interest
calculated at the Fixed Rate pursuant to subparagraph 2(b)(ii) below,
interest shall accrue on the principal balance of this Note at the Variable
Rate. The initial Variable Rate shall be equal to the "LIBOR INDEX" (defined
below) as of the date the Loan converts to the Permanent Loan, plus two and
three-fourths percentage points (2.750%) per annum, rounded to the next
highest one-eighth of one percent (0.125%). The Variable Rate, if applicable,
will change five (5) months after the first payment date stated in
subparagraph 3(b) below, and every sixth (6th) month thereafter (each such
date being referred to in this Note as an "INTEREST CHANGE DATE").
(1) LIBOR INDEX - CURRENT INDEX - Changes in the
Variable Rate will be based on changes in the 180-day LIBOR as defined below
(the "LIBOR INDEX"). If the LIBOR Index is no longer available, the Holder
will choose a new index based upon comparable information and give Maker
notice of the choice. The most recently available LIBOR Index fifteen (15)
Business Days before each Interest Change Date is the "CURRENT INDEX" .
(2) CALCULATION OF VARIABLE RATE - Before each Interest
Change Date, if applicable, the Holder will calculate the new Variable Rate
which shall be equal to the Current Index, plus two and three-fourths
percentage points (2.750%) per annum, rounded to the next highest one-eighth
of one percent (0.125%). This new interest rate will be the Variable Rate
until the next Interest Change Date.
(3) LIBOR MEANS THE LONDON INTERBANK OFFER RATE,
adjusted at the Holder's option for statutory reserves, deposit insurance,
regulatory capital, taxes and assessments, if any, and is the average of the
rates of interest, on a per annum basis, at which deposits in United States
dollars having a term of 180 days are offered by major banks in immediately
available funds to prime banks in the London Interbank market at 11:00 A.M.
(London time) on the date the Loan converts to a Permanent Loan, or the day
which is fifteen (15) Business Days prior to the applicable Interest Change
Date, as applicable. This rate is reported on Telerate, a national and
international medium which provides interest rate quotations daily, as quoted
by the British Bankers Association as Interest Settlement Rates on page 3750
(or such other page as may replace it). Such interest rate quotation, as
provided by Telerate, shall be deemed conclusive and final with respect to
LIBOR determinations for so long as Telerate continues to make such interest
rate reports. If Telerate or the British Bankers Association report is no
longer available for 180-day maturities, a comparable publication or report
containing such information selected by the Holder will be used. If there is
no such publication or comparable publication containing such information,
the 180-day LIBOR shall be the average rate (rounded if necessary to the
nearest one thousandth of a percent) at which dollar deposits having a
maturity of 180 days are offered by at least two major banks in an
2
interbank market where Eurodollars are being traded to prime banks in
immediately available funds on the LIBOR determination date described above
or as soon thereafter as such offer quotes can be obtained.
(4) BUSINESS DAY means a day on which commercial banks
are generally open for business in Seattle, Washington and London, England.
(5) The amount of adjustment for reserves, deposit
insurance, regulatory capital, taxes and assessments may change on any
Interest Change Date depending on such charges then being assessed against
the Holder. Such charges may change due to various factors, including but not
limited to, changes in the requirements for reserves and capital adequacy
promulgated by the Federal Reserve System of the United States and/or other
state and federal regulatory agencies, statutory changes affecting the
Holder, and/or imposition of taxes, FDIC fees and/or assessments. Each
determination of an adjustment amount shall be made by the Holder in its sole
and absolute discretion and shall be conclusive and binding upon Maker and
shall be determined without benefit of or credit for prorations, exceptions
or offsets that may be available to the Holder from time to time.
(ii) FIXED RATE. Prior to the date the Loan converts to the
Permanent Loan, Maker may elect by written notice to the Holder to have
interest on the entire principal amount of this Note calculated for the
entire term of the Permanent Loan at a Fixed Rate, as provided below.
Further, so long as Maker is not in default under the terms of this Note or
any Loan Document, at any time after the Loan converts to the. Permanent
Loan, Maker at its option, and upon the payment of a fee to the Holder equal
to 0.250% of the then outstanding principal balance of this Note (or $500.00,
whichever is greater), may elect by written notice to the Holder to have
interest calculated on the entire principal balance of this Note at a Fixed
Rate calculated as provided below for the remainder of the term of the
Permanent Loan. Maker's ability to fix the interest rate on this Note
pursuant to this subparagraph 2(b)(ii) is subject to the availability to the
Holder of matchfunding opportunities for a time period equivalent to the term
of this Note following the date of Maker's election to fix the interest rate.
(1) CALCULATION OF FIXED RATE - If Maker elects to have a
Fixed Rate apply to this Note, interest shall accrue on the principal balance
of this Note at a per annum rate equal to Lender's reserve adjusted "Fixed
Rate Index" as quoted by Lender on the date the interest rate is converted to
the Fixed Rate, for a period equivalent to the term of the Permanent Loan (or
remainder thereof, as applicable), plus two and thirty-three one-hundredths
percentage points (2.330%) per annum, rounded upward to the next highest
one-eighth of one percent (0.125%). The Fixed Rate Index may be adjusted at
the Holder's option to reflect statutory reserves, deposit insurance,
regulatory capital, taxes and assessments, if any, as set forth in
subparagraph 2(b)(i)(5) above.
(2) DATE OF CONVERSION - The interest rate will be
converted to the Fixed Rate on the date the Holder receives Maker's written
notice electing the Fixed Rate option, provided such notice is received before
noon, Seattle time, on a Business Day, and the fee payable in connection with
the election has been received by Holder. If notice is received by Holder after
noon, Seattle time, on a Business Day, the interest rate applicable to this
Note will convert to a Fixed Rate on the next Business Day. For purposes of
this subparagraph 2(b)(ii)(2) only, the term "BUSINESS DAY" means a day on
which commercial banks are generally open for business in Seattle,
Washington.
3. PAYMENTS.
(a) CONSTRUCTION TERM PAYMENTS. During the Construction Term, Maker
shall make monthly payments of interest on this Note as it accrues. Payments
shall be due on the first day of each calendar month during the Construction
Term, commencing on the first day of the first calendar month following the
initial advance by the Holder under this Note.
(b) PERMANENT LOAN PAYMENTS. If the Loan converts to the Permanent
Loan, Maker shall make monthly payments of principal and interest to the
Holder, in amounts sufficient to
3
fully amortize the principal balance of this Note over a twenty (20) year
amortization period in substantially equal payments, based on the interest
rate applicable to this Note, calculated as provided below. Such monthly
payments of principal and interest shall be due on the first day of each
calendar month during the term of the Permanent Loan, commencing on the first
day of the second calendar month following the month in which the Loan
converts to the Permanent Loan. The monthly payments required on this Note
following conversion to the Permanent Loan shall be calculated as follows:
(i) VARIABLE RATE PAYMENTS. If interest is accruing on this
Note at a Variable Rate, the amount of the initial monthly payments shall be
in an amount sufficient to fully amortize the principal balance of this Note
at the initial Variable Rate, in substantially equal monthly payments over
the amortization period specified above. PROMPTLY AFTER THE LOAN CONVERTS TO
THE PERMANENT LOAN, THE HOLDER WILL PROVIDE MAKER WITH A CLOSING STATEMENT
(OR OTHER WRITTEN NOTICE) WHICH WILL CONFIRM THE INITIAL VARIABLE RATE AND
THE AMOUNT OF THE INITIAL PRINCIPAL AND INTEREST PAYMENTS DUE UNDER THIS
NOTE. The monthly payment will change after each Interest Change Date to an
amount sufficient to repay the then unpaid principal balance of this Note in
full at the then current interest rate, in substantially equal monthly
payments over the balance of the amortization period specified above. Until
the payment is again changed, Maker shall pay the new monthly payment each
month beginning on the first day of the first calendar month after the
applicable Interest Change Date. The Holder will mail or deliver to Maker a
notice of any changes in the interest rate applicable to this Note, and any
resulting changes in the monthly payments required under this Note, prior to
the date the first payment is due after the applicable Interest Change Date.
(ii) FIXED RATE PAYMENTS. If interest is accruing on this
Note at a Fixed Rate, the amount of the monthly payments shall be in an
amount sufficient to fully amortize the principal balance of this Note at the
applicable Fixed Rate, in substantially equal monthly payments over the
amortization period specified above, or the remainder thereof, as applicable.
THE APPLICABLE FIXED RATE AND THE AMOUNT OF THE MONTHLY PRINCIPAL AND
INTEREST PAYMENTS DUE UNDER THIS NOTE SHALL BE CONFIRMED IN WRITING BY THE
HOLDER (EITHER PURSUANT TO A CLOSING STATEMENT OR OTHER WRITTEN NOTICE) AFTER
THE INTEREST RATE IS FIXED AND PRIOR TO THE DATE THE FIRST PAYMENT IS DUE AT
THE FIXED RATE.
(c) GENERAL. At the option of the Holder, all payments under this
Note, including payment at maturity, shall be made in same day funds. On the
Maturity Date (as the same may be extended as provided in this Note), the
unpaid principal balance of this Note, all unpaid accrued interest and all
other sums then due and owing pursuant to this Note or any other Loan
Document shall be due and payable in full. Each payment shall be applied
first, at Holder's option, to any unpaid late charges or other sums payable
by Maker under this Note or any other Loan Document, then to interest to the
due date of the payment, and then to the principal balance of this Note.
4. AUTOMATIC WITHDRAWAL. The payments on this Note and any other sums
secured by the Deed of Trust will be deducted on the first (lst) day of each
month from Seafirst Deposit Account No. 0000000, or such other Seafirst
Deposit Account as may be authorized in the future.
5. LATE CHARGES; RETURNED ITEM FEE. If any payment due hereunder is not
received by the Holder within fifteen (15) days of the due date, at the
option of the Holder without waiving such default or any of its remedies, a
late charge shall be added to the delinquent payment in the amount of four
percent (4%) of the full payment not timely paid. Any such late charge shall
be due and payable on demand, and the Holder, at its option, may (a) refuse
any late payment or any subsequent payment unless accompanied by the
applicable late charge, (b) add the late charge to the principal balance of
this Note, (c) pay any late charge with advances of the undisbursed proceeds
of the Loan, if any, or (d) treat the failure to pay the late charge as
demanded as a default under this Note. If a late charge is added to the
principal balance of this Note, it shall bear interest at the same rate as
the principal balance of this Note. Any payment to Holder by check, draft or
other item shall be received by Holder subject to collection and will
constitute payment when collected not when received. For each "nsf' or
returned check, draft or other item, in addition to any applicable late
charge, Maker shall pay to the Holder on demand a returned item fee in
accordance with the Holder's schedule of such fees then in effect.
4
6. PREPAYMENT. During the Construction Term, and thereafter, so long as
interest is calculated on this Note at a Variable Rate, this Note may be
prepaid in whole or in part, at any time, without payment of a prepayment
fee. During any period when a Fixed Rate is applicable to this Note, this
Note may be prepaid only as set forth in EXHIBIT A attached. Partial
prepayments, if permitted, shall not postpone nor reduce the amount of the
monthly payments required under this Note.
7. DEFAULT. After a default under any of the Loan Documents, or if Maker
fails to make any payment under this Note when due, the Holder, at its
option, without notice to Maker (except as provided below), may declare the
entire principal balance of this Note and all unpaid accrued interest thereon
and other charges payable by Maker pursuant to this Note or any other Loan
Document immediately due and payable in full, and the Holder may exercise any
and all other rights or remedies available to it under any Loan Document, at
law or in equity. Any additional interest due because of a default shall
accrue from the date of default and shall be paid as a condition to the
curing of the default. Notwithstanding the foregoing, the Holder will not
accelerate the Maturity Date (a) because of a monetary default by Maker under
this Note or any other Loan Document unless the default is not cured within
ten (10) days of the date on which the Holder mails or delivers written
notice of the default to Maker, or (b) because of a nonmonetary default by
Maker under this Note or any other Loan Document unless the default is not
cured within thirty (30) days of the date on which the Holder mails or
delivers written notice of the default to Maker. For purposes of this Note,
the term "MONETARY DEFAULT" means a failure by Maker to make any payment
required pursuant to this Note or any other Loan Document, and the term
"NONMONETARY DEFAULT" shall mean a failure by Maker to perform any obligation
contained in this Note or any other Loan Document, other than the obligation
to make the payments provided for in this Note or any other Loan Document. If
the nonmonetary default is capable of being cured and cannot reasonably be
made within the thirty (30) day cure period, the cure period shall be
extended up to ninety (90) days so long as Maker has commenced action to cure
within the thirty (30) day cure period, and in the Holder's opinion, Maker is
proceeding to cure the default with due diligence. None of the foregoing
shall be construed to obligate the Holder to forbear in any other manner from
exercising its remedies and the Holder may pursue any other rights or
remedies which the Holder may have because of the default.
8. CUMULATIVE REMEDIES. The rights and remedies of any Holder under this
Note or any other Loan Document, or at law or in equity, shall be cumulative
and concurrent, may be pursued singly, successively or together against
Maker, any guarantor of this Note, or any security for this Note. A failure
by any Holder to exercise its option to accelerate this Note upon the
occurrence of a default or to exercise any other rights to which it may be
entitled shall not constitute a waiver of the right to exercise such option
or any such rights in the event of any subsequent default, whether of the
same or a different nature.
9. WAIVERS. Maker and all endorsers, guarantors and all other persons or
entities who may become liable for all or any part of the obligations
evidenced by this Note, jointly and severally: waive diligence, presentment,
protest and demand, and also notice of protest, demand, non- payment,
dishonor or maturity and also recourse to suretyship defenses generally; and
consent to any and all renewals, extensions and modifications of the terms of
this Note or any other Loan Document, including the time for payment, and
agree any such renewal, extension or modification or the release or
substitution of any security for the indebtedness evidenced by this Note or
any other indulgences, shall not affect the liability of said parties for the
indebtedness evidenced by this Note. Any such renewals, extensions,
modifications, releases or indulgences may be made without notice to such
parties.
10. COSTS AND EXPENSES. Whether or not suit is brought Maker shall pay
on demand all costs and expenses, including attorneys' fees and costs and
allocated costs of in-house legal counsel, incurred by or on behalf of the
Holder in connection with this Note, including without limitation costs
incurred in the collection of this Note, in protecting the security for this
Note or in foreclosing or enforcing this Note or any other Loan Document, or
resulting from the Holder being made a party to any litigation because of the
existence of this Note or any other Loan Document. Without limiting the
generality of the foregoing, if Maker becomes the subject of any bankruptcy or
5
insolvency proceeding, Maker shall pay all fees and expenses incurred by the
Holder in connection with such bankruptcy or insolvency proceeding.
11. MAXlMUM INTEREST. Maker represents and warrants the proceeds of this
Note shall be used solely for commercial, investment and business purposes,
and not for personal, family or household purposes. Notwithstanding any
other provision of this Note or any other Loan Document, interest, loan fees
and charges payable by reason of the indebtedness evidenced by this Note
shall not exceed the maximum, if any, permitted by applicable law. If by
virtue of applicable law, sums in excess of such maximum would otherwise be
payable, then such excess sums shall be construed as having been immediately
applied by the Holder to the principal balance of this Note when received. If
at the time any such sum is received by the Holder, the principal balance of
this Note has been paid in full, such sums shall be promptly refunded by the
Holder to Maker, less any sums due to the Holder.
12. SECURlTY. This Note is secured by a deed of trust dated December 10,
1995 (the "DEED OF TRUST") encumbering certain real property located in
Spokane County, Washington (the "PROPERTY"). Unless otherwise specified in
this Note, all notices given pursuant to this Note must be in writing and
will be effectively given if given in accordance with the terms of the Deed
of Trust.
13. GENERAL. This Note shall be binding upon Maker and Maker's
beneficiaries, heirs, devisees, personal representatives, successors and
assigns. If Maker consists of more than one person or entity, all of such
persons and entities shall be jointly and severally liable for Maker's
obligations under this Note. This Note is governed by and shall be construed
in accordance with the laws of the State of Washington. Each person or entity
executing this Note consents to the non-exclusive personal jurisdiction and
venue of the courts of the State of Washington and the United States federal
courts located therein, in any action relating to or arising out of the
enforcement or interpretation of this Note or any other Loan Document. Each
such person or entity further agrees not to assert in any such action that
the proceeding has been brought in an inconvenient forum.
14. ARBITRATION. Any dispute relating to this Note or the Loan (whether
in contract or tort) shall be settled by arbitration if requested by Maker,
the Holder or any other party to the dispute (such as a guarantor); PROVIDED,
both Maker and the Holder must consent to a request for arbitration relating
to an obligation secured by real property. The arbitration proceedings shall
be held in Seattle, Washington in accordance with the commercial arbitration
rules of the American Arbitration Association, and the United States
Arbitration Act (i.e., Title 9, U.S.C.). There shall be one arbitrator who
shall decide whether an issue is arbitrable or whether any claim is barred by
a statute of limitations. Judgment on the arbitration award may be entered in
any court having jurisdiction. Commencement of a lawsuit shall not constitute
a waiver of the right of any party to request arbitration if the lawsuit is
contested. Each party shall have the right before, during and after the
commencement of any arbitration proceeding to exercise any of the following
remedies, in any order or concurrently: (i) self-help remedies such as setoff
or repossession; (ii) judicial or nonjudicial foreclosure against real or
personal property collateral; and (iii) provisional remedies including
injunction, appointment of receiver, attachment, claim and delivery and
replevin. The exercise of any such remedy shall not waive a party's right to
request arbitration. Nothing in this paragraph shall limit in any way any
right the Holder may have to foreclose the Deed of Trust judicially as a
mortgage, or nonjudicially pursuant to the power of sale.
15. DISPUTED OBLIGATIONS. ALL COMMUNICATIONS CONCERNING DISPUTED DEBTS
AND OBLIGATIONS OF MAKER UNDER THIS NOTE OR ANY OTHER LOAN DOCUMENT,
INCLUDING WITHOUT LIMITATION DISPUTES AS TO THE AMOUNT OF ANY PAYMENT, FEE OR
CHARGE, AND INCLUDING AN INSTRUMENT TENDERED AS FULL SATISFACTION OF A
DISPUTED DEBT, MUST BE IN WRITING AND MUST BE SENT TO THE FOLLOWING ADDRESS,
OR TO SUCH OTHER ADDRESS AS THE HOLDER MAY HEREAFTER SPECIFY:
SEAFIRST BANK
ATTENTION: LOAN SERVICING MANAGER
REAL ESTATE GROUP (CSC-14)
000 XXXXX XXXXXX, XXXXX 00
XXXXXXX, XXXXXXXXXX 00000
6
ANY SUCH COMMUNICATION SHOULD INCLUDE THE NAME OF MAKER, THE APPLICABLE LOAN
NUMBER, A DESCRIPTION OF THE DISPUTE AND THE RELIEF OR REMEDY REQUESTED, AND AN
ADDRESS AND TELEPHONE NUMBER WHERE THE PERSON SENDING THE NOTICE CAN BE
CONTACTED.
NOTICE: ORAL AGREEMENTS OR ORAL COMMITMENTS TO LOAN MONEY, EXTEND CREDIT OR
FORBEAR FROM ENFORCING REPAYMENT OF A DEBT ARE NOT ENFORCEABLE UNDER WASHINGTON
LAW.
MAKER:
THE COEUR D'ALENES COMPANY,
an Idaho corporation
By: /s/ Xxxxxxx Xxxxxxxxx
-----------------------
Its: Treas.
-----------------------
7
[Letterhead]
Loan No 604938 and 453817-9
SUBORDINATION AGREEMENT
NOTICE: THIS SUBORDINATION AGREEMENT RESULTS IN THE SUBORDINATING PARTY'S
SECURITY INTEREST IN THE PROPERTY BECOMING SUBJECT TO AND OF LOWER PRIORITY
THAN THE LIEN OF SOME LATER OR OTHER SECURITY INSTRUMENT.
1. THE HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES
DUE OCTOBER 31, 1998 ("Subordinator"), is the owner and holder of the
following documents executed by The Coeur d'Alenes Company, an Idaho
corporation (hereafter collectively referred to as the "Second Deed Of
Trust"):
(a) DEED OF TRUST dated October 29, 1993, recorded November 5,
1993, under Auditor's File No. 9311050174, records of Spokane County,
Washington. Auditor's File No.
2. SEATTLE-FIRST NATIONAL BANK, a national banking association
("Lender") is the owner and holder of the following documents executed by The
Coeur d'Alenes Company, an Idaho corporation (hereinafter collectively
referred to as the "First Deed of Trust"):
(a) DEED OF TRUST dated December 20, 1995, recorded , under records
of Spokane County.
3. THE COEUR D'ALENES COMPANY, an Idaho corporation, ("Owner") is the
owner of all the real property described in the First Deed of Trust.
4. In consideration of benefits to Subordinator from Owner, receipt
and sufficiency of which is hereby acknowledged, and to induce Lender to
advance funds under its First Deed of Trust and all agreements in connection
therewith, Subordinator hereby unconditionally subordinates the lien,
security interest and rights granted by the Second Deed of Trust to the lien,
security interest and rights granted by the First Deed of Trust and to all
advances or charges made or accruing under the First Deed of Trust, including
any extension or renewal thereof, to the same effect as though the First Deed
of Trust had been placed on record before the Second Deed of Trust.
5. It is understood and agreed that a default under the First Deed of
Trust shall constitute a default under the Second Deed of Trust, and
Subordinator, upon such default, may, at its option, without demand or
notice, declare the whole sum secured by the Second Deed of Trust with
interest thereon to be immediately due and payable, or Subordinator may, at
its option, cure the default and add any amounts paid in curing the default
to the amount due under the Second Deed of Trust without waiving any of its
rights under the Second Deed of Trust or the Note which it secures.
6. Subordinator acknowledges that, prior to the execution of this
Agreement, Subordinator has had the opportunity to examine the terms of the
First Deed of Trust, Note and agreements relating thereto which Subordinator
consents to and approves. Subordinator acknowledges that Lender has no
obligation to Subordinator to advance any funds under the First Deed of Trust
or see to the application of any funds advanced. Any application or use of
such funds for purposes other than those provided for in the First Deed of
Trust, Note or other agreements shall not defeat this subordination in whole
or in part.
-1-
7. It is understood by the parties hereto that Lender would not make
the loan secured by the First Deed of Trust Without this Agreement
8. This Agreement shall be the whole and only agreement between the
parties hereto with regard to the subordination of the Second Deed of Trust
to the First Deed of Trust, and shall supercede and cancel any prior
agreements regarding subordination including, but not limited to, those
provisions, if any, contained in the Second Deed of Trust which provides for
the subordination of the lien or charge thereof to a deed of trust or deeds
of trust to be thereafter executed.
9. This Subordination Agreement is entered into by Subordinator only
and solely for the benefit of the present and future owners and holders of
the indebtedness secured by the First Deed of Trust and not for the benefit
of, nor in favor of, any other person or party. The Second Deed of Trust is
in full force and effect and asserted by Subordinator except as expressly
hereby subordinated.
10. This Subordination Agreement shall not impair the validity or
priority of the Second Deed of Trust as to real property not described in the
First Deed of Trust.
ll. It is contemplated that this Subordination Agreement will be filed
for record after the First Deed of Trust is filed, and Subordinates
specifically authorizes Lender or its agent to insert in this Agreement where
indicated the actual filing dates and number of the First Deed of Trust and
such insertions shall be binding upon Subordinator.
12. The heirs, administrators, assigns and successors in interest of
Subordinator shall be bound by this Agreement. The words "Deed of Trust"
shall refer to "mortgage" where appropriate.
Executed this 5th day of February, 1996.
--- -------- -
NOTICE: THIS SUBORDINATION AGREEMENT CONTAINS A PROVISION WHICH ALLOWS ThE
OWNER TO OBTAIN A LOAN SECURED BY A LIEN WHICH WILL HAVE PRIORITY OVER THE
SUBORDINATING PARTY'S LIEN AND ALL OR A PORTION OF THE LOAN MAY BE EXPENDED
FOR PURPOSES OTHER THAN IMPROVEMENT OF THE REAl PROPERTY. IT IS RECOMMENDED
THAT, PRIOR TO THE EXECUTION OF THIS SUBORDINATION AGREEMENT, THE PARTIES
CONSULT WITH THEIR ATTORNEYS.
OWNER: SUBORDINATOR:
THE COEUR D'ALENES COMPANY, THE HOLDERS OF THE COEUR D'ALENES
an Idaho corporation COMPANY'S CONVERTIBLE DEBENTURES
DUE OCTOBER 31, 1998,
By: By: /S/X.X. Xxxxxxx, (1)
---------------------------- -------------------------------
Its: Its: General Partner
--------------------------- -----------------------------
By: (2)
------------------------------
Sigma FBO Xxxxxx X. Xxxxxxxxx
Its:
------------------------------
By: (3)
------------------------------
Xxx Xxxxxx
By: (4)
------------------------------
Xxxxxxx Xxxxxx
By: /S/ Xxxxx X. Xxxx (5)
------------------------------
Xxxxx X. Xxxx
By: Xxxx Xxxx (6)
------------------------------
Xxxx Xxxx
-2-
STATE OF WASHINGTON )
)
COUNTY OF SPOKANE )
I hereby certify that I know of have satisfactory evidence that Xxxxxxxx X.
Xxxxxxx is the person who appeared before me, that said person acknowledged
that he signed this instrument, on oath stated he was authorized to execute
the instrument and acknowledge it as the general partner of C.I.N.V., a
Washington partnership, to be the free and voluntary act of such party for
the uses and purposes mentioned in the instrument.
GIVEN UNDER my hand and official seal this 6th Day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
--------------------------------------
(Print Notary Name) Xxxxxxxx X Xxxxxx
------------------
Notary Public in and for the State of Washington
residing at Greenacres
---------------------
My appointment expires 8-27-99
--------
STATE OF WASHINGTON )
)Section
COUNTY OF )
I hereby certify that I know of have satisfactory evidence that (4)
______________, is the person who appeared before me, that said person
acknowledged that he/she signed this instrument, on oath stated he/she was
authorized to execute the instrument and acknowledge it as the
_______________ of THE HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE
DEBENTURES DUE OCTOBER 31, 1998, to be the free and voluntary act of such
party for the uses and purposes mentioned in the instrument.
GIVEN UNDER my hand and official seal this ___ day of _________________.
--------------------------------------
(Print Notary Name)
------------------
Notary Public in and for the State of Washington
residing at
---------------------
My appointment expires
--------
STATE OF WASHINGTON )
)Section
COUNTY OF SPOKANE )
I hereby certify that I know of have satisfactory evidence that Xxxxx Xxxx, (5)
is the person who appeared before me, that said person acknowledged that
he/she signed this instrument, on oath stated he/she was authorized to
execute the instrument and acknowledge it as the _________________ of THE
HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER
31, 1998, to be the free and voluntary act of such party for the uses and
purposes mentioned in the instrument.
GIVEN UNDER my hand and official seal this 6th Day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
--------------------------------------
(Print Notary Name) Xxxxxxxx X Xxxxxx
------------------
Notary Public in and for the State of Washington
residing at Greenacres
---------------------
My appointment expires 8-27-99
--------
STATE OF WASHINGTON )
)Section
COUNTY OF SPOKANE )
I hereby certify that I know of have satisfactory evidence that Xxxx Xxxx, (6)
is the person who appeared before me, that said person acknowledged that
he/she signed this instrument, on oath stated he/she was authorized to execute
the instrument and acknowledge it as the _______________ of THE HOLDERS OF THE
COEUR D'ALENES COMPANY'S CONVERTIBLE DEBENTURES DUE OCTOBER 31, 1998, to be
the free and voluntary act of such party for the uses and purposes mentioned
in the instrument.
GIVEN UNDER my hand and official seal this 6th Day of February, 1996.
/S/ Xxxxxxxx X. Xxxxxx
--------------------------------------
(Print Notary Name) Xxxxxxxx X Xxxxxx
------------------
Notary Public in and for the State of Washington
residing at Greenacres
---------------------
My appointment expires 8-27-99
--------
-4-
STATE OF WASHINGTON )
)Section
COUNTY OF )
I hereby certify that I know of have satisfactory evidence that (2)
______________, is the person who appeared before me, that said person
acknowledged that he/she signed this instrument, on oath stated he/she was
authorized to execute the instrument and acknowledge it as the
_______________ of THE HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE
DEBENTURES DUE OCTOBER 31, 1998, to be the free and voluntary act of such
party for the uses and purposes mentioned in the instrument.
GIVEN UNDER my hand and official seal this ___ day of _________________.
--------------------------------------
(Print Notary Name)
------------------
Notary Public in and for the State of Washington
residing at
---------------------
My appointment expires
--------
STATE OF WASHINGTON )
)Section
COUNTY OF )
I hereby certify that I know of have satisfactory evidence that (3)
______________, is the person who appeared before me, that said person
acknowledged that he/she signed this instrument, on oath stated he/she was
authorized to execute the instrument and acknowledge it as the
_______________ of THE HOLDERS OF THE COEUR D'ALENES COMPANY'S CONVERTIBLE
DEBENTURES DUE OCTOBER 31, 1998, to be the free and voluntary act of such
party for the uses and purposes mentioned in the instrument.
GIVEN UNDER my hand and official seal this ___ day of _________________.
--------------------------------------
(Print Notary Name)
------------------
Notary Public in and for the State of Washington
residing at
---------------------
My appointment expires
--------
-5-