1
EXHIBIT 10.39
EXODUS COMMUNICATIONS, INC.
INTERNET DATA CENTER SERVICES AGREEMENT
THIS INTERNET DATA CENTER SERVICES AGREEMENT (this "Agreement") is made
effective as of the Submission Date (November 10, 1997) indicated in the
initial Internet Data Center Services Order Form accepted by Exodus, by and
between Exodus Communications, Inc. ("Exodus") and the customer identified below
("Customer").
PARTIES:
CUSTOMER NAME: E-Loan, Inc.
---------------------------------------------------------
ADDRESS: 000 Xxxxxxxxxx Xxx. Xxx. 000
---------------------------------------------------------
Xxxx Xxxx, XX 00000
---------------------------------------------------------
PHONE: 000-000-0000
---------------------------------------------------------
FAX: 000-000-0000
---------------------------------------------------------
EXODUS COMMUNICATIONS, INC.
0000 Xxx Xxxxx Xxxxxxxxxx
Xxxxx Xxxxx, XX 00000
Phone: (000) 000-0000
Fax: (000) 000-0000
1. INTERNET DATA CENTER SERVICES.
Subject to the terms and conditions of this Agreement, during the term of this
Agreement, Exodus will provide to Customer the services described in the
Internet Data Center Services Order Form(s) ("IDC Services Order Form(s)")
accepted by Exodus, or substantially similar services if such substantially
similar services would provide Customer with substantially similar benefits
("Internet Data Center Services"). All IDC Services Order Forms accepted by
Exodus are incorporated herein by this reference, each as of the Submission Date
indicated in such form.
2. FEES AND BILLING.
2.1 Fees. Customer will pay all fees due according to the IDC Services
Order Form(s).
2.2 Billing Commencement. Billing for Internet Data Center Services,
other than Setup Fees, indicated in the initial IDC Services Order Form shall
commence on the earlier to occur of (i) the "Installation Date" indicated in the
initial IDC Services Order Form, regardless of whether Customer has commenced
use of the Internet Data Center Services, unless Customer is unable to install
the Customer Equipment and/or use the Internet Data Center Services by the
Installation Date due to the fault of Exodus, then billing will not begin until
the date Exodus has remedied such fault and (ii) the date the "Customer
Equipment" (Customer's computer hardware and other tangible equipment, as
identified in the Customer Equipment List which is incorporated herein by this
reference) is placed by Customer in the "Customer Area" (the portion(s) of the
Internet Data Centers, as defined in Section 3.1 below, made available to
Customer hereunder for the placement of Customer Equipment) and is operational.
All Setup Fees will be billed upon receipt of a Customer signed IDC Services
Order Form. In the event that Customer orders additional Internet Data Center
Services, billing for such services shall commence on the date Exodus first
provides such additional Internet Data Center Services to Customer or as
otherwise agreed to by Customer and Exodus.
2.3 Billing and Payment Terms. Customer will be billed monthly in
advance of the provision of Internet Data Center Services, and payment of such
fees will be due within thirty (30) days of the date of each Exodus invoice. All
payments will be made in U.S. dollars. Late payments hereunder will accrue
interest at a rate of one and one-half percent (1 -1/2%) per month, or the
highest rate allowed by applicable law, whichever is lower. If in its judgment
Exodus determines that Customer is not creditworthy or is otherwise not
financially secure, Exodus may, upon written notice to Customer, modify the
payment terms to require full payment before the provision of Internet Data
Center Services or other assurances to secure Customer's payment obligations
hereunder.
2.4 Taxes. All payments required by this Agreement are exclusive of all
national, state, municipal or other governmental excise, sales, value-added,
use, personal property, and occupational taxes, excises, withholding taxes and
obligations and other levies now in force or enacted in the future, all of which
Customer will be responsible for and will pay in full, except for taxes based on
Exodus' net income.
3. CUSTOMER'S OBLIGATIONS.
3.1 Compliance with Law and Rules and Regulations. Customer agrees that
Customer will comply at all times with all applicable laws and regulations and
Exodus' general rules and regulations relating to its provision of Internet Data
Center Services, as updated by Exodus from time to time ("Rules and
Regulations"). Customer acknowledges that Exodus exercises no control whatsoever
over the content of the information passing through its sites containing the
Customer Area and equipment and facilities used by Exodus to provide Internet
Data Center Services ("Internet Data Centers"), and that it is the sole
responsibility of Customer to ensure that the information it transmits and
receives complies with all applicable laws and regulations.
3.2 Customer's Costs. Customer agrees that it will be solely
responsible, and at Exodus's request will reimburse Exodus, for all costs and
expenses (other than those included as part of the Internet Data Center Services
and except as otherwise expressly provided herein) it incurs in connection with
this agreement.
3.3 Access and Security. Customer will be fully responsible for any
charges, costs, expenses (other than those included in the Internet Data Center
Services), and third party claims that may result from its use of, or access to,
the Internet Data Centers and/or the Customer Area including but not limited to
any unauthorized use of any access devices provided by Exodus hereunder. Except
with the advanced written consent of Exodus, Customer's access to the Internet
Data Centers will be limited solely to the individuals identified and authorized
by Customer to have access to the Internet Data Centers and the Customer Area in
accordance with this Agreement, as identified in the Customer Registration Form,
as amended from time to time, which is hereby incorporated by this reference
("Representatives").
3.4 No Competitive Services. Customer may not at any time permit any
Internet Data Center Services to be utilized for the provision of any services
that compete with any Exodus services, without Exodus' prior written consent.
3.5 Insurance.
(a) Minimum Levels. Customer will keep in full force and effect during
the term of this Agreement: (i) comprehensive general liability insurance in an
amount not less than $5 million per occurrence for bodily injury and property
damage; (ii) employer's liability insurance in an amount not less than $1
million per occurrence; and (iii) workers' compensation insurance in an amount
not less than that required by applicable law. Customer also agrees that it
will, and will be solely responsible for ensuring that its agents (including
contractors and subcontractors) maintain, other insurance at levels no less than
those required by applicable law and customary in Customer's and its agents'
industries.
(b) Certificates of Insurance. Prior to installation of any Customer
Equipment in the Customer Area, Customer will furnish Exodus with certificates
of insurance which evidence the minimum levels of insurance set forth above.
(c) Naming Exodus as an Additional Insured. Customer agrees that prior
to the installation of any Customer Equipment, Customer will cause its insurance
provider(s) to name Exodus as an additional insured and notify Exodus in writing
of the effective date thereof.
4. CONFIDENTIAL INFORMATION.
4.1 Confidential Information. Each party acknowledges that it will have
access to certain confidential information of the other party concerning the
other party's business, plans, customers, technology, and products, including
the terms and conditions of this Agreement ("Confidential Information").
Confidential Information will include, but not be limited to, each party's
proprietary software and customer information. Each party agrees that it will
not use in any way, for its own account or the account of any third party,
except as expressly permitted by this Agreement, nor disclose to any third party
(except as required by law or to that party's attorneys, accountants and other
advisors as reasonably necessary), any of the other party's Confidential
Information and will take reasonable precautions to protect the confidentiality
of such information.
4.2 Exceptions. Information will not be deemed Confidential Information
hereunder if such information: (i) is known to the receiving party prior to
receipt from the disclosing party directly or indirectly from a source other
than one having an obligation of confidentiality to the disclosing party; (ii)
becomes known (independently of disclosure by the disclosing party) to the
receiving party directly or indirectly from a source other than one having an
obligation of confidentiality to the disclosing party; (iii) becomes publicly
known or otherwise ceases to be secret or confidential, except through a breach
of this Agreement by the receiving party; or (iv) is independently developed by
the receiving party.
5. REPRESENTATIONS AND WARRANTIES.
5.1 Warranties by Customer.
(a) Customer Equipment. Customer represents and warrants that it owns
or has the legal right and authority, and will continue to own or maintain the
legal right and authority during the term of this Agreement, to place and use
the Customer Equipment as contemplated by this Agreement. Customer further
represents and warrants that its placement, arrangement, and use of the Customer
Equipment in the Internet Data Centers complies with the Customer Equipment
Manufacturer's environmental and other specifications.
(b) Customer's Business. Customer represents and warrants that
Customer's services, products, materials, data, information and Customer
Equipment used by Customer in connection with this Agreement as well as
Customer's and its permitted customers' and users' use of the Internet Data
Center Services (collectively, "Customer's Business") does not as of the
Installation Date, and will not during the term of this Agreement operate in any
manner that would violate any applicable law or regulation.
(c) Rules and Regulations. Customer has read the Rules and Regulations
and represents and warrants that Customer and Customer's Business are currently
in full compliance with the Rules and Regulations, and will remain so at all
times during the term of this Agreement.
(d) Breach of Warranties. In the event of any breach, or reasonably
anticipated breach, of any of the foregoing warranties, in addition to any other
remedies available at law or in equity, Exodus will have the right immediately,
in Exodus' sole discretion, to suspend any related Internet Data Center Services
if deemed reasonably necessary by Exodus to prevent any harm to Exodus and its
business.
5.2 Warranties and Disclaimers by Exodus.
(a) Service Level Warranty. In the event Customer is unable to transmit
and receive information from Exodus' Internet Data Centers to other portions of
the Internet and
EXODUS COMMUNICATIONS, INC. CONFIDENTIAL (REV 10/97) PAGE 1
2
Customer notifies Exodus immediately of such event and Exodus determines in its
reasonable judgment that such inability was caused by Exodus' failure to provide
Internet Data Center Services for reasons within Exodus' reasonable control and
not as a result of any actions or inactions of Customer or any third parties
(including failure of third party equipment), Exodus will, upon Customer's
request, credit Customer's account as follows: If Exodus failed to provide the
Internet Data Center Services for (i) more than two (2) consecutive hours in a
calendar month, Exodus will credit Customer's account the connectivity charges
for one (1) day of service; and (ii) more than eight (8) consecutive hours in a
calendar month, Exodus will credit Customer's account the connectivity charges
for one (1) week of service. Customer may receive only one of the foregoing
credits in any single calendar month, regardless of the number of such
occurrences. Exodus' scheduled maintenance of the Internet Data Centers and
Internet Data Center Services, as described in the Rules and Regulations, shall
not be deemed to be a failure of Exodus to provide Internet Data Center
Services. THIS WARRANTY DOES NOT APPLY TO ANY INTERNET DATA CENTER SERVICES THAT
EXPRESSLY EXCLUDE THIS WARRANTY. THIS SECTION 5.2(a) STATES CUSTOMER'S SOLE AND
EXCLUSIVE REMEDY (OTHER THAN TERMINATION OF THIS AGREEMENT) FOR ANY FAILURE BY
EXODUS TO PROVIDE INTERNET DATA CENTER SERVICES.
(b) No Other Warranty. EXCEPT FOR THE EXPRESS WARRANTY SET OUT IN
SUBSECTION (a) ABOVE, THE INTERNET DATA CENTER SERVICES ARE PROVIDED ON AN "AS
IS" BASIS, AND CUSTOMER'S USE OF THE INTERNET DATA CENTER SERVICES IS AT ITS OWN
RISK. EXODUS DOES NOT MAKE, AND HEREBY DISCLAIMS, ANY AND ALL OTHER EXPRESS
AND/OR IMPLIED WARRANTIES, INCLUDING, BUT NOT LIMITED TO, WARRANTIES OF
MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, NONINFRINGEMENT AND TITLE,
AND ANY WARRANTIES ARISING FROM A COURSE OF DEALING, USAGE, OR TRADE PRACTICE.
EXODUS DOES NOT WARRANT THAT THE INTERNET DATA CENTER SERVICES WILL BE
UNINTERRUPTED, ERROR-FREE, OR COMPLETELY SECURE.
(c) Disclaimer of Actions Caused by and/or Under the Control of Third
Parties. EXODUS DOES NOT AND CANNOT CONTROL THE FLOW OF DATA TO OR FROM EXODUS'
INTERNET DATA CENTERS AND OTHER PORTIONS OF THE INTERNET. SUCH FLOW DEPENDS IN
LARGE PART ON THE PERFORMANCE OF INTERNET SERVICES PROVIDED OR CONTROLLED BY
THIRD PARTIES. AT TIMES, ACTIONS OR INACTIONS CAUSED BY THESE THIRD PARTIES CAN
PRODUCE SITUATIONS IN WHICH EXODUS' CUSTOMERS' CONNECTIONS TO THE INTERNET (OR
PORTIONS THEREOF) MAY BE IMPAIRED OR DISRUPTED. ALTHOUGH EXODUS WILL USE
COMMERCIALLY REASONABLE EFFORTS TO TAKE ACTIONS IT DEEMS APPROPRIATE TO REMEDY
AND AVOID SUCH EVENTS, EXODUS CANNOT GUARANTEE THAT THEY WILL NOT OCCUR.
ACCORDINGLY, EXODUS DISCLAIMS ANY AND ALL LIABILITY RESULTING FROM OR RELATED TO
SUCH EVENTS.
6. LIMITATIONS OF LIABILITY.
6.1 Personal Injury. EACH REPRESENTATIVE AND ANY OTHER PERSONS VISITING
THE INTERNET DATA CENTERS DOES SO AT ITS OWN RISK AND EXODUS ASSUMES NO
LIABILITY WHATSOEVER FOR ANY HARM TO SUCH PERSONS RESULTING FROM ANY CAUSE OTHER
THAN EXODUS' GROSS NEGLIGENCE OR WILLFUL MISCONDUCT RESULTING IN PERSONAL INJURY
TO SUCH PERSONS DURING SUCH A VISIT.
6.2 Damage to Customer Equipment or Business. EXODUS ASSUMES NO
LIABILITY FOR ANY DAMAGE TO, OR LOSS RELATING TO, CUSTOMER'S BUSINESS RESULTING
FROM ANY CAUSE WHATSOEVER. CERTAIN CUSTOMER EQUIPMENT, INCLUDING BUT NOT LIMITED
TO CUSTOMER EQUIPMENT LOCATED ON CYBERRACKS, MAY BE DIRECTLY ACCESSIBLE BY OTHER
CUSTOMERS. EXODUS ASSUMES NO LIABILITY FOR ANY DAMAGE TO, OR LOSS OF, ANY
CUSTOMER EQUIPMENT RESULTING FROM ANY CAUSE OTHER THAN EXODUS' GROSS NEGLIGENCE
OR WILLFUL MISCONDUCT. TO THE EXTENT EXODUS IS LIABLE FOR ANY DAMAGE TO, OR LOSS
OF, THE CUSTOMER EQUIPMENT FOR ANY REASON, SUCH LIABILITY WILL BE LIMITED SOLELY
TO THE THEN-CURRENT VALUE OF THE CUSTOMER EQUIPMENT.
6.3 Exclusions. EXCEPT AS SPECIFIED IN SECTIONS 6.1 AND 6.2, IN NO
EVENT WILL EXODUS BE LIABLE TO CUSTOMER, ANY REPRESENTATIVE, OR ANY THIRD PARTY
FOR ANY CLAIMS ARISING OUT OF OR RELATED TO THIS AGREEMENT, CUSTOMER EQUIPMENT,
CUSTOMER'S BUSINESS OR OTHERWISE, AND ANY LOST REVENUE, LOST PROFITS,
REPLACEMENT GOODS, LOSS OF TECHNOLOGY, RIGHTS OR SERVICES, INCIDENTAL, PUNITIVE,
INDIRECT OR CONSEQUENTIAL DAMAGES, LOSS OF DATA, OR INTERRUPTION OR LOSS OF USE
OF SERVICE OR OF ANY CUSTOMER EQUIPMENT OR CUSTOMER'S BUSINESS, EVEN IF ADVISED
OF THE POSSIBILITY OF SUCH DAMAGES, WHETHER UNDER THEORY OF CONTRACT, TORT
(INCLUDING NEGLIGENCE), STRICT LIABILITY OR OTHERWISE.
6.4 Maximum Liability. NOTWITHSTANDING ANYTHING TO THE CONTRARY IN THIS
AGREEMENT, EXODUS'S MAXIMUM AGGREGATE LIABILITY TO CUSTOMER RELATED TO OR IN
CONNECTION WITH THIS AGREEMENT WILL BE LIMITED TO THE TOTAL AMOUNT PAID BY
CUSTOMER TO EXODUS HEREUNDER FOR THE PRIOR TWELVE (12) MONTH PERIOD.
6.5 Customer's Insurance. Customer agrees that it will not pursue any
claims against Exodus for any liability Exodus may have under or relating to
this Agreement until Customer first makes claims against Customer's insurance
provider(s) and such insurance provider(s) finally resolve(s) such claims.
6.6 Basis of the Bargain; Failure of Essential Purpose. Customer
acknowledges that Exodus has set its prices and entered into this Agreement in
reliance upon the limitations of liability and the disclaimers of warranties and
damages set forth herein, and that the same form an essential basis of the
bargain between the parties. The parties agree that the limitations and
exclusions of liability and disclaimers specified in this Agreement will survive
and apply even if found to have failed of their essential purpose.
7. INDEMNIFICATION.
7.1 Exodus' Indemnification of Customer. Exodus will indemnify, defend
and hold Customer harmless from and against any and all costs, liabilities,
losses, and expenses (including, but not limited to, reasonable attorneys' fees)
(collectively, "Losses") resulting from any claim, suit, action, or proceeding
(each, an "Action") brought against Customer alleging (i) the infringement of
any third party registered U.S. copyright or issued U.S. patent resulting from
the provision of Internet Data Center Services pursuant to this Agreement (but
excluding any infringement contributorily caused by Customer's Business or
Customer Equipment) and (ii) personal injury to Customer's Representatives from
Exodus's gross negligence or willful misconduct.
7.2 Customer's Indemnification of Exodus. Customer will indemnify,
defend and hold Exodus, its affiliates and customers harmless from and against
any and all Losses resulting from or arising out of any Action brought by or
against Exodus, its affiliates or customers alleging: (a) with respect to the
Customer's Business: (i) infringement or misappropriation of any intellectual
property rights; (ii) defamation, libel, slander, obscenity, pornography, or
violation of the rights of privacy or publicity; or (iii) spamming, or any other
offensive, harassing or illegal conduct or violation of the Rules and
Regulations; (b) any damage or destruction to the Customer Area, the Internet
Data Centers or the equipment of Exodus or any other customer by Customer or
Representative(s) or Customer's designees; or (c) any other damage arising from
the Customer Equipment or Customer's Business.
7.3 Notice. Each party will provide the other party prompt written
notice upon of the existence of any such event of which it becomes aware, and an
opportunity to participate in the defense thereof.
8. TERM AND TERMINATION.
8.1 Term. This Agreement will be effective for a period of one (1) year
from the Installation Date, unless earlier terminated according to the
provisions of this Section 8. The Agreement will automatically renew for
additional terms of one (1) year each.
8.2 Termination.
(a) For Convenience.
(i) By Customer During First Thirty Days. Customer may terminate this
Agreement for convenience by providing written notice to Exodus at any time
during the thirty (30) day period beginning on the Installation Date.
(ii) By Either Party. Either party may terminate this Agreement for
convenience at any time effective after the first (1st) anniversary of the
Installation Date by providing ninety (90) days' prior written notice to the
other party at any time thereafter.
(b) For Cause. Either party will have the right to terminate this
Agreement if: (i) the other party breaches any material term or condition of
this Agreement and fails to cure such breach within thirty (30) days after
receipt of written notice of the same, except in the case of failure to pay
fees, which must be cured within five (5) days after receipt of written notice
from Exodus; (ii) the other party becomes the subject of a voluntary petition in
bankruptcy or any voluntary proceeding relating to insolvency, receivership,
liquidation, or composition for the benefit of creditors; or (iii) the other
party becomes the subject of an involuntary petition in bankruptcy or any
involuntary proceeding relating to insolvency, receivership, liquidation, or
composition for the benefit of creditors, if such petition or proceeding is not
dismissed within sixty (60) days of filing.
8.3 No Liability for Termination. Neither party will be liable to the
other for any termination or expiration of this Agreement in accordance with its
terms.
8.4 Effect of Termination. Upon the effective date of expiration or
termination of this Agreement: (a) Exodus will immediately cease providing the
Internet Data Center Services; (b) any and all payment obligations of Customer
under this Agreement will become due immediately; (c) within thirty (30) days
after such expiration or termination, each party will return all Confidential
Information of the other party in its possession at the time of expiration or
termination and will not make or retain any copies of such Confidential
Information except as required to comply with any applicable legal or accounting
record keeping requirement; and (d) Customer will remove from the Internet Data
Centers all Customer Equipment and any of its other property within the Internet
Data Centers within five (5) days of such expiration or termination and return
the Customer Area to Exodus in the same condition as it was on the Installation
Date, normal wear and tear excepted. If Customer does not remove such property
within such five-day period, Exodus will have the option to (i) move any and all
such property to secure storage and charge Customer for the cost of such removal
and storage, and/or (ii) liquidate the property in any reasonable manner.
8.5 Customer Equipment as Security. In the event that Customer fails to
pay Exodus all amounts owed Exodus under this Agreement when due, Customer
Agrees that upon written notice, Exodus may take possession of any Customer
Equipment and store it, at Customer's expense, until taken in full or partial
satisfaction of any lien or judgment, all without being liable to prosecution or
for damages.
8.6 Survival. The following provisions will survive any expiration or
termination of the Agreement: Sections 2, 3, 4, 5, 6, 7, 8 and 9.
9. MISCELLANEOUS PROVISIONS.
9.1 Force Majeure. Except for the obligation to pay money, neither
party will be liable for any failure or delay in its performance under this
Agreement due to any cause beyond its reasonable control, including act of war,
acts of God, earthquake, flood, embargo, riot, sabotage, labor shortage or
dispute, governmental act or failure of the Internet, provided that the delayed
party: (a) gives the other party prompt notice of such cause, and (b) uses its
reasonable commercial efforts to correct promptly such failure or delay in
performance.
9.2 No Lease. This Agreement is a services agreement and is not
intended to and will not constitute a lease of any real or personal property.
Customer acknowledges and agrees that (i) it has been granted only a license to
occupy the Customer Space and use the Internet Data Centers and any equipment
provided by Exodus in accordance with this Agreement, (ii) Customer has not been
granted any real property interest in the Customer Space or Internet Data
Centers, and (iii) Customer has no rights as a tenant or otherwise under any
real property or landlord/tenant laws, regulations, or ordinances. For good
cause, including the exercise of any rights under Section 8.5 above, Exodus may
suspend the right of any Representative or other person to visit the Internet
Data Centers.
EXODUS COMMUNICATIONS, INC. CONFIDENTIAL (REV 10/97) PAGE 2
3
9.3 Marketing. Customer agrees that Exodus may refer to Customer by
trade name and trademark, and may briefly describe Customer's Business, in
Exodus' marketing materials and web site. Customer hereby grants Exodus a
license to use any Customer trade names and trademarks solely in connection with
the rights granted to Exodus pursuant to this Section 9.3.
9.4 Government Regulations. Customer will not export, re-export,
transfer, or make available, whether directly or indirectly, any regulated item
or information to anyone outside the U.S. in connection with this Agreement
without first complying with all export control laws and regulations which may
be imposed by the U.S. Government and any country or organization of nations
within whose jurisdiction Customer operates or does business.
9.5 Non-Solicitation. During the period beginning on the Installation
Data and ending on the first anniversary of the termination or expiration of
this Agreement in accordance with its terms, Customer agrees that it will not,
and will ensure that its affiliates do not, directly or indirectly, solicit or
attempt to solicit for employment any persons employed by Exodus during such
period.
9.6 Governing Law; Dispute Resolution, Severability; Waiver. This
Agreement is made under and will be governed by and construed in accordance with
the laws of the State of California (except that body of law controlling
conflicts of law) and specifically excluding from application to this Agreement
that law known as the United Nations Convention on the International Sale of
Goods. Any dispute relating to the terms, interpretation or performance of this
Agreement (other than claims for preliminary injunctive relief or other
pre-judgment remedies) will be resolved at the request of either party through
binding arbitration. Arbitration will be conducted in Santa Xxxxx County,
California, under the rules and procedures of the Judicial Arbitration and
Mediation Society ("JAMS"). The parties will request that JAMS appoint a single
arbitrator possessing knowledge of online services agreements; however the
arbitration will proceed even if such a person is unavailable. In the event any
provision of this Agreement is held by a tribunal of competent jurisdiction to
be contrary to the law, the remaining provisions of this Agreement will remain
in full force and effect. The waiver of any breach or default of this Agreement
will not constitute a waiver of any subsequent breach or default, and will not
act to amend or negate the rights of the waiving party.
9.7 Assignment; Notices. Neither party may assign its rights or
delegate its duties under this Agreement either in whole or in part without the
prior written consent of the other party, except that this Agreement may be
assigned in whole as part of a corporate reorganization, consolidation, merger,
or sale of substantially all of its assets. Any attempted assignment or
delegation without such consent will be void. This Agreement will bind and inure
to the benefit of each party's successors and permitted assigns. Any notice or
communication required or permitted to be given hereunder may be delivered by
hand, deposited with an overnight courier, sent by confirmed facsimile, or
mailed by registered or certified mail, return receipt requested, postage
prepaid, in each case to the address of the receiving party indicated on the
signature page hereof, or at such other address as may hereafter be furnished in
writing by either party hereto to the other. Such notice will be deemed to have
been given as of the date it is delivered, mailed or sent, whichever is earlier.
9.8 Relationship of Parties. Exodus and Customer are independent
contractors and this Agreement will not establish any relationship of
partnership, joint venture, employment, franchise or agency between Exodus and
Customer. Neither Exodus nor Customer will have the power to bind the other or
incur obligations on the other's behalf without the other's prior written
consent, except as otherwise expressly provided herein.
9.9 Entire Agreement; Counterparts. This Agreement, including all
documents incorporated herein by reference, constitutes the complete and
exclusive agreement between the parties with respect to the subject matter
hereof, and supersedes and replaces any and all prior or contemporaneous
discussions, negotiations, understandings and agreements, written and oral,
regarding such subject matter. This Agreement may be executed in two or more
counterparts, each of which will be deemed an original, but all of which
together shall constitute one and the same instrument.
Customer's and Exodus' authorized representatives have read the foregoing and
all documents incorporated therein and agree and accept such terms effective as
of the date first above written.
CUSTOMER EXODUS COMMUNICATIONS, INC.
Signature: /s/ Xxxxx Xxxxxx Signature: /s/ Illegible
---------------------------- ----------------------------
Print Name: Xxxxx Xxxxxx Print Name: Illegible
--------------------------- ---------------------------
Title: President Title: Illegible
-------------------------------- --------------------------------
EXODUS COMMUNICATIONS, INC. CONFIDENTIAL REV 10/97) Page 3
