EXHIBIT 10.3
WEB SITE DEVELOPMENT AGREEMENT FOR THE
CREATION OF TWO NEW WEB SITES FOR
XXXXXXXXXXXXX.XXX
DATED OCTOBER 25, 1999
16
NK DL
---- ----
WEB SITE DEVELOPMENT AGREEMENT
FOR THE CREATION OF TWO NEW WEB SITES
FOR XXXXXXXXXXXXX.XXX
This Web Site Development Agreement (this "Agreement") is made this
25th day of October, 1999, (the "Effective Date) by and between xXxxXxxxxxx.xxx,
Inc. (the "Developer" ) and XxXxxxxxxxxxx.xxx, Inc. (the "Customer").
A G R E E M E N T:
1. SERVICES TO BE RENDERED. The Developer will perform web development
work for the Customer as more particularly described in Exhibit A, which is
attached hereto and incorporated into this Agreement. All services provided by
the Developer to the Customer are defined as the "Services," any and all
resulting work product is the "Product," and any task discretely listed on
Exhibit A, attached hereto, is the "Task") If Exhibit A lists an estimated date
or time for completion ("Estimated Completion Date") for any Task, the Developer
shall use best efforts to complete the Task by such Estimated Completion Date.
However, the Developer cannot guarantee that any Task will be complete on the
Estimated Completion Date. If Exhibit A does not list any Estimated Completion
Date for any Task, the Developer will use best efforts to complete such Task
within a reasonable period of time.
2. PAYMENT OF FEES. In consideration of the Services, the Customer
shall pay Developer, the fees (the "Fees") more particularly described in
Exhibit B, which is attached hereto and incorporated into this Agreement.
3. INDEMNIFICATION.
(a) INDEMNIFICATION BY CUSTOMER. The Customer agrees to
indemnify, defend and hold the Developer, it's owners and its agents,
officers, directors, lawyers, accountants, and employees, harmless from and
against any and all losses, claims, demands, damages, liabilities, costs and
expenses, including but not limited to reasonable attorneys' fees and the
costs of any legal action arising from Customer's web site(s) or Customer's
use of the Services. Such indemnification shall include, but not be limited
to, claims for libel, slander, infringement of copyright, theft of
misappropriation of intellectual property, or unauthorized use of any
trademark, trade name, or service xxxx.
17
NK DL
---- ----
(b) INDEMNIFICATION BY DEVELOPER. Except as otherwise herein
provided, the Developer agrees to indemnify, defend and hold the Customer and
its agents, officers, directors, lawyers, and accountants harmless from and
against any and all losses, claims, demands, damages, liabilities, costs and
expenses, including but not limited to, reasonable attorneys' fees and costs of
any legal action (but excluding consequential damages) arising from the
Developer's gross negligence in the course of providing the Services under this
agreement. In no event will the Developer be liable for lost or damaged data,
loss of business, or anticipatory profits, or any other consequential or
incidental damages resulting from the use or operation of the Services or the
maintenance thereof.
4. LIMITATION OF DAMAGES. The Developer will endeavor to
provide high quality Services and a high quality Product. However, the
Developer is not, and will not be responsible for any consequential or
incidental damages resulting from any malfunctioning of Customer's web site
resulting form Developer's Services, including, but not limited to, any
interruptions of service, or data loss (including lost transactions), unless
such damages arose from Developer's gross negligence. In an event involving
gross negligence on the part of the Developer, the liability shall be limited
to the sum of three thousand dollars ($3,000.00) per day. Although the
Developer will endeavor to safeguard any data provided by the Customer, the
Customer agrees that it is responsible for safeguarding its data, including
maintaining backup data sets.
5. TERMINATION OF AGREEMENT.
(a) MATERIAL BREACH. If either party is in material breach
this Agreement, the non-breaching party may serve the breaching party with a
written notice specifying the material breach and requesting the breaching party
to cure it. If the breaching party fails to cure the material breach within ten
(10) days after its receipt of the notice, the non-breaching party may terminate
this Agreement by sending a written notice of termination to the breaching
party. The termination of this Agreement shall take effect immediately on the
receipt of such notice of termination by the breaching party.
(b) TERMINATION ABSENT A BREACH. Neither party shall have the
ability to unilaterally terminate the Agreement, except as specifically
permitted by provisions of this Agreement. A party specifically granted the
ability to terminate this Agreement for any reason not covered by subsection (a)
of this Paragraph , may exercise this right by sending the other party a written
notice stating that it is terminating the Agreement and citing the specific
paragraph and subparagraph providing the party with the ability to terminate the
Agreement. The termination of this agreement shall take effect thirty (30) days
following the other party's receipt of this notice. This sub-paragraph shall not
apply to any termination arising from a material breach.
(c) EFFECT OF TERMINATION. On any termination of this
Agreement, the Developer may immediately cease providing Services to the
Customer, and neither party shall have any further obligation to the other under
the Agreement, provided that neither party shall be relieved from any
obligations or liabilities arising under the Agreement prior to its termination.
If the Developer has not provided substantially all of the Services listed in
Exhibit A prior to the termination of this Agreement, the Developer shall be
entitled to retain not less than the number
18
NK DL
---- ----
of Shares (as defined in Exhibit B) necessary to compensate the Developer at
the rate one hundred twenty-five dollars ($125.) per man hour for the
Services actually rendered, based on a price of one dollar and twenty-five
cents ($1.25) per Share, which the parties agree is the fair market value of
the Customer's common stock on the date this Agreement is signed.
6. WARRANTIES; LIMITATIONS ON LIABILITY. THE DEVELOPER MAKES NO
WARRANTY, REPRESENTATION, OR PROMISE NOT EXPRESSLY SET FORTH IN THIS AGREEMENT.
EXCEPT AS OTHERWISE EXPRESSLY SET FORTH HEREIN THE SERVICES ARE PROVIDED "AS
IS." THE DEVELOPER DISCLAIMS AND EXCLUDES ANY AND ALL IMPLIED WARRANTIES OF
MERCHANTABILITY, TITLE AND FITNESS OF THE SERVICES FOR A PARTICULAR PURPOSE. THE
DEVELOPER DOES NOT WARRANT THAT THE SERVICES OR RELATED MATERIALS WILL SATISFY
CUSTOMER'S REQUIREMENTS OR THAT THE SERVICES AND RELATED SERVICES WILL BE
WITHOUT DEFECT OR ERROR.
7. ENTIRE AGREEMENT. This Agreement supersedes all previous agreements
between the parties, contains the entire understanding between the parties, and
may not be changed, except in writing, duly executed by each of the parties.
8. INDEPENDENT CONTRACTOR. The Developer is an independent contractor
relative to the Customer and nothing contained herein shall be deemed to create
a partnership or agency relationship.
9. ASSIGNMENT. This agreement may not be assigned without the express
written consent of the non-assigning party.
10. NOTICES. All notices required by this Agreement shall be in writing
and sent by Facsimile, Electronic Mail, Federal Express, or U.S. Mail, Return
Receipt Requested as provided below. Such notice shall be sufficient for the
purposes of this Agreement only if sent to the party's "Address for Service" as
listed below. Such Address for Service may be changed by any party by serving
notice (in compliance with the paragraph) on the other party. No notice sent by
facsimile shall be sufficient without a confirmation receipt. No notice sent by
electronic mail shall be sufficient unless sent to an address included in the
recipient's Address for Service and acknowledged by a human-generated response.
Developer's Address for Service:
Address: Attn: Xxxxxx Xxxxxx
00000 Xxxxxxx Xxx., Xxxxx 000
Xxxxxxxx, XX 00000
19
NK DL
---- ----
Fax: (000) 000-0000
E-mail: xxxxxxx@xxxxxxxxxxx.xxx
Customer's Address for Service:
Address: Attn: Xxxxx Xxxxxxxx
000 X. Xxxxxxxxx Xxxx., Xxxxx 000
Xxx Xxxxxxx, Xxxxxxxxxx 00000
Fax: (000) 000-0000
E-mail: xxxx@xxxxxxxxxxxxxx.xxx
11. DISPUTE RESOLUTION. If a dispute or claim shall arise with respect
to any of the terms or provisions of this Agreement, then either party may, by
notice as herein provided, require that the dispute be submitted under the
Commercial Arbitration Rules of the American Arbitration Association to an
arbitrator in good standing with the American Arbitration Association within
fifteen (15) days after such notice is given. Any such arbitrator so selected is
to be mutually acceptable to both parties. If both parties are unable to agree
upon a single arbitrator, each party shall appoint one (1) arbitrator. If either
party does not appoint an arbitrator within five (5) days after the other party
has given notice of the name of its arbitrator, the single arbitrator appointed
by the party giving notice shall be the sole arbitrator and such arbitrator's
decision shall be binding upon both parties. If two (2) arbitrators are
appointed, these two (2) arbitrators shall appoint a third arbitrator who shall
proceed to resolve the question. The written decision of the single arbitrator
ultimately appointed by or for both parties shall be binding and conclusive on
the parties. Judgment may be entered on such written decision by the single
arbitrator in any court having jurisdiction and the parties consent to the
jurisdiction of Orange County, California for this purpose. Any arbitration
undertaken pursuant to the terms of this section shall occur in Orange County,
California.
12. ATTORNEYS' FEES. In the event of any legal, equitable or
administrative action or proceeding brought by any party against another party
under this Agreement, the prevailing party shall be entitled to recover the
reasonable fees of its attorneys and any costs incurred in such action or
proceeding including costs of appeal, if any, in such amount that the court or
administrative body having jurisdiction over such action may award.
13. GOVERNING LAW. This Agreement will be construed and enforced in
accordance with, and governed by, the laws of the State of California in the
United States of America without giving effect to any conflict of laws
principles. The parties hereby consent to the personal jurisdiction of the
courts of the County of Orange, California, and waive any rights to change
venue.
20
NK DL
---- ----
14. CURRENCY DENOMINATIONS. All currency denominations are in United
States dollars.
IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be
duly executed and delivered as of the date first written above.
The Developer
XXXXXXXXXXX.XXX, INC.
By: /s/ X. XXXX
------------------------------------
Its: CEO/PRESIDENT
-----------------------------------
The Customer
XxXxxxxxxxxxx.xxx, Inc.
By: /s/ XXXXX XXXXXXXX
------------------------------------
Xxxxx Xxxxxxxx
President/CEO
21
EXHIBIT A
SERVICES
The Developer will create a new web site to replace the Customer's
existing web site at xxxx://xxx.xxxxxxxxxxxxx.xxx (the "RxAlternative Site") and
a new web site to be hosted as xxxx://xxx.xxxxxxxxxxxx.xxx. (the "InterNatural
Site"). (These sites are also referred to as the "Web Sites")
A. The Developer shall construct the RxAlternativeWeb Sites in three phases as
follows:
Phase I. Inception Phase.
In Phase I, the Developer will work with the Customer to analyze the
Customer's requirements for the Web Site. Based on the Customer's requirements,
the Developer will determine what data will need to be gathered and what
processes will be needed for the Web Site. After performing data modeling and
analysis, the Developer will design any needed databases for the Web Site. The
Developer will work with the Customer to develop a "Demo" site, displaying the
"look and feel" of the Web Site.
Phase II. Development Phase.
In Phase II, the Developer will construct the Web Site, coding the
HTML, developing graphics, and installing the following services: (a) a shopping
cart, (b) a search engine, (c) a client survey, (d) a discussion board, (e)
e-mail automation (enabling the Web Site to automatically send out email
notifications to users), (g) registration and member validation processes, (h)
an automatic payment solution, and (i) Virtual MD (a database configured to
function as an online medical advisor to users).
Phase III. Testing and Hosting
In Phase III, the Developer will perform (a) Alpha testing, (b) Beta
testing, and (c) Site Testing.
B. The Developer shall construct the InterNatural Site, coding the HTML,
developing graphics, and installing the following services: (a) a shopping cart,
(b) a search engine, (c) registration and member validation processes, and (d)
an automatic payment solution.
22
LIST OF xXxxXxxxxxx.xxx REQUIREMENTS FROM RXALTERNATIVE Page 1 of 8
EXHIBIT A
NO REQUIREMENTS DESCRIPTION
------------------------------------------------------------------------------------------------------------------------------------
I DATABASE
1 Product Containing detailed product data, department (See page 11)
2 News Containing news data
3 Articles Library Containing articles data
4 Encyclopedia Containing related library of definitions, symptoms, etc.
5 Books Containing books database related to Rx Products
6 Referral Containing Data of Doctors
7 Artificial Intelligence Containing Question and Answer + keywords that point to certain product +
product to product relationship + other criteria
8 Survey Survey Contents
II BUSINESS PROCESS
1 Data Flow for Contents Flowchart of the contents flow when customers visit the site and go to
library of articles, news, encyclopedia and books.
2 Data Flow for Shopping Cart Flowchart of the product navigation, purchase, and other processes,
when customers visit the site and purchase the product
3 Data Flow for Search Engine Flowchart of the product, news, articles, books, other subjects,
when customers visit the site
4 Data Flow for Virtual Doctor Flowchart of the virtual doctor using questions/special keywords/
product to product relationships/etc
5 Data Flow for Email Account Flowchart of the email account assignments
6 Data Flow for Discussion Board Flowchart of discussion board for customers (general topics)
7 Data Flow for 'AskDoctor' Flowchart of discussion board for customers to discuss their problem
doctors/specialists
8 Data Flow for Help Desk Flowchart of help desk that contains FAQ, explanation to certain words, etc
9 Data Flow for Chat Room Flowchart of real time discussion between doctors, consumers,
customer support, etc.
10 Data Flow for Site Map Flowchart of site map
III SITE LAYOUT & GRAPHICS
LOGO
New logo based on Site Layout (for presentation)
COLOR SCHEME
Color Scheme based on Site Layout (for presentation)
SITE FUNCTIONALITIES
Functionality of the site for ex: product, library, etc.
LAYOUT
The basic layout of the site (with top frame, left and right frame, and
bottom frame and the contents in the center)
GRAPHICS
Graphic animation for logo, virtual doctor, and other still pictures for
buttons
23
EXHIBIT A Page 2 of 8
PRODUCT DATABASE SPECIFICATION
RxAlternative is expected to provide a product database based on the
specifications provided below.
----------------------------------------------------------------------------------------------------------
TABLE NAME FIELDS NAME NOTE
----------------------------------------------------------------------------------------------------------
CATEGORY category_id ID of Product Category
cat_title Category Title
cat_description Category Description
----------------------------------------------------------------------------------------------------------
SUBCATEGORY subcategory_id ID of Product Sub-Category
subcat_title Sub-Category Title
subcat_description Sub-Category Description
----------------------------------------------------------------------------------------------------------
VENDOR vendor_id ID of Vendor
vendor_title Vendor Title
vendor_description Vendor Description
----------------------------------------------------------------------------------------------------------
PRODUCT product_id ID of product (to uniquely identify the product)
product_title Title of product (formally)
product_shortdesc Product Short Description
product_longdesc Product Long Description
price Retail Price
dsicount_price Discount Price (if any)
smallimage Small image the product (put file name)
largeimage Large image the product (put file name)
quantity The total number of products in the inventory
availability The availability of product, ex: 'usually 24 hours,'
usually 2-3 days,' etc.)
type Type of the product: BOOK, VIDEO, AUDIO, MEDICINE, other
category?)
subcategory_id Sub-Category ID based on SUBCATEGORY Table)
keywords All important words associated to the product that could
speed up and focus the search.
----------------------------------------------------------------------------------------------------------
AUDIO product_id ID of product (to uniquely identify the product)
time_length length in minutes of the audio
performer performer's name
format Cassette or CD
----------------------------------------------------------------------------------------------------------
VIDEO product_id ID of product (to uniquely identify the product)
time_length length in minutes of the audio
performer performer's name
format DVD/VHS/other?
----------------------------------------------------------------------------------------------------------
BOOK product_id ID of product (to uniquely identify the product)
author_fname First Name of Author
author_lname Last Name of Author
publisher Publisher Name
ISBN ISBN (Number to uniquely identify the book)
edition The Edition (1st, 2nd, etc)
pub_date Book Publishing Date
format Format of book whether: hardcopy, softcopy, large size, etc.
----------------------------------------------------------------------------------------------------------
MEDICINE product_id ID of product (to uniquely identify the product)
sale_unit See 'Sale Unit' in the Book (xxxxxxxxxxxx.xxx)
case_lot See 'Case Lot' in the Book (xxxxxxxxxxxx.xxx)
ingredients Ingredients of each product
product_interactions interaction between one product to other products
product symptoms relationship between products and symptoms
----------------------------------------------------------------------------------------------------------
24
EXHIBIT A
PRODUCT DATABASE DIAGRAM
B category_id B product_id B product_id
cat_title minute_length sale_unit
cat_description peformer case_lot
format ingredients
product_interaction
product_symptoms
B product_id
product_title
B category_id B subcategory_id product_shortdesc
B subcategory_id product_longdesc
B vendor_id subcat_description price
discount_price
smallimage
largeimage
quantity
B product_id availability
author_lname category
author_fname subcategory_id B product_id
publisher keywords time_length
B vendor_id sbn performer
vendor_title edition format
vendor_description pubdate
format
REQUIRED SOFTWARE AND HARDWARE LIST Page 4 of 8
EXHIBIT A
---------------------------------------- ------------------------------ ------------------------------------------ ---------------
SOFTWARE PURPOSE VENDOR
------------------------------------------ ---------------
ALT 1 ALT 2 ALT 3 ALT 4
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
SYSTEM SOFTWARE X X X X Microsoft
Windows NT Server 4.0 for the Operating System
Enterprise
Internet Information Server 4.0 Web Server
Microsoft Back Office Server 4.5
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
DATABASE SOFTWARE
SQL server 7.0 for the Enterprise Database Server X
Microsoft
Oracle 8I Enterprise Edition Database Server
2 yrs license with 500 MHz Processor X Oracle
4 yrs license with 500 MHz Processor X
Lifetime with 500 MHz Processor
X
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
WEB APPLICATION SERVER
ColdFusion Application Server Web Application Server X X X X Xxxxxxx
4.5 Enterprise Edition
Xxxxxxx Spectra 1.0 Content X X X X Xxxxxxx
Management/Personalization
Macromedia Generator 2.0 Generate/automate Flash content X X X X Macromedia
Macromedia Drumbeat 2000 e-commerce Generate Active Server
Edition Pages X X X X Macromedia
NetObject Fusion Authoring Content Contributor X X X X NetObjects
Server Server
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
HTML/COLDFUSION EDITORS
ColdFusion Studio 4.0 Create ColdFusion X X X X Xxxxxxx
applications
Dreamweaver 3.0 Create Dynamic HTML content X X X X Macromedia
NetObject Fusion 4.0 Create HTML, ASP, JSP pages X X X X NetObjects
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
2D GRAPHIC SOFTWARE
Adobe Photoshop Create/Edit 2D graphic X X X X Adobe
content
Adobe Illustrator Create/Edit 2D Vector X X X X Adobe
graphics
Fireworks 3.0 Optimize graphics for web X X X X Macromedia
KPT Vector Effects 1.5 Creative Plug-in for Adobe X X X X Metacreations
Illustrator
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
3D GRAPHIC SOFTWARE
Metacreation Poser 4.0 Create 3D human figures X X X X Metacreations
Metacreations Bryce 4.0 Create 3D environments X X X X Metacreations
3Dstudio Max Release 3.0 Create/Edit/Design/Animate X X X X Kinetix
3D Graphics
Character Studio Release 2.2 Animate 3D human figures X X X X Kinetix
Canoma Convert 2D photos to 3D X X X X Metacreations
designs
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
STREAMING MEDIA
Flash 4.0 create streaming media X X X X Macromedia
(vector)
Director 7.0 create streaming media X X X X Macromedia
(raster)
VivoActiveVideoNow 3.0 create/serve streaming X VivoSoftware
videos
RealServer Professional create/serve streaming X X X RealNetworks
videos
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
WEB APPLICATIONS
AbleCommerce Developer 2.9 Shopping Cart X X X X AbleCommerce
Xxxxxxx Forums Bulletin/Discussion Board X X X X Xxxxxxx
Xxxxxx Artificial Intelligence X X X X pdv
Chat Chat Room X X X X Chatspace
Survey Online Survey X X X X
Global Site Plus Service 128-bit SSL, $250K X X X X Verisign
Netsure, free security and
site performance audits
Automate Payment Services Online Credit Card X X X X Verisign
Authorization
Setup Fee X X X X
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
WEB STATISTIC ANALYSIS
WebTrends Enterprise Suite Traffic Analysis X X X X WebTrends
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
HARDWARE: SERVERS
Dual-Processor Pentium III Xeon Data Server X X X X SAG Electronics
550 MHz
Dual-Processor Pentium III 600 Web Hosting Server X X X X SAG Electronics
MHz
---------------------------------------- ------------------------------ --------- ---------- ---------- ---------- ---------------
The Customer will purchase or advance all the expenses associated with
acquisition, setup, installation and hosting of the above software and hardware
for the development and maintenance of the Web Site.
CHART OMITTED
CHART OMITTED
NEW RXALTERNATIVE SITE FEATURES
EXHIBIT A
--------- ------------------------------------- ----------------------------------------------------------------------------------
NO DESCRIPTION NOTE
--------- ------------------------------------- ----------------------------------------------------------------------------------
I VIRTUAL DOCTOR (VD)
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Graphic Animation Using Flash 4.0 Virtual Doctor Picture
and DHTML
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 Personalization - Customizing VD according to user profiles
- Maintaining User Personal Data
--------- ------------------------------------- ----------------------------------------------------------------------------------
3 Artificial Intelligence behind the Logic that controls the behavior of VD supported by database. The database
scene Q/A, product to product interaction, product to symptom relationship, or product
to medical problem relationship.
--------- ------------------------------------- ----------------------------------------------------------------------------------
II SHOPPING CART
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Product Naviation Product Catalog with description, pictures, price.
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 Product Cart Cart of Products when customer decides to buy.
--------- ------------------------------------- ----------------------------------------------------------------------------------
3 Product Search Engine The ability to search the products.
--------- ------------------------------------- ----------------------------------------------------------------------------------
4 Processing The processafter customer decides t check-out: customer data, credit card, and
shopping basket will be inserted to database.
--------- ------------------------------------- ----------------------------------------------------------------------------------
5 Automate Payment Verification Credit Card will be verified by Credit Card Verification Company like: Cybercash,
PaymentNet, etc.
--------- ------------------------------------- ----------------------------------------------------------------------------------
6 Data Encryption/Security Using Security Software provided by Verisign or other vendors to secure the
transaction processing
--------- ------------------------------------- ----------------------------------------------------------------------------------
7 Account History The ability to keep User's History in the database, and keep track of them.
--------- ------------------------------------- ----------------------------------------------------------------------------------
8 Personalization The ability to offer certain customers with special products, or same products
that they have ordered, or other related products.
--------- ------------------------------------- ----------------------------------------------------------------------------------
III SEARCH ENGINE
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Search Product based on keywords, The ability to search products based nkeywords, department, or product name
department, or product name.
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 Search News The ability to search News based on keywords
--------- ------------------------------------- ----------------------------------------------------------------------------------
3 Search Article/Library The ability to search Articles based on keywords
--------- ------------------------------------- ----------------------------------------------------------------------------------
4 Search in Encyclopedia The ability to search Encyclopedia based on keywords
--------- ------------------------------------- ----------------------------------------------------------------------------------
5 Search Referrals The ability to search Referrals based on keywords
--------- ------------------------------------- ----------------------------------------------------------------------------------
IV DISCUSSION BOARD
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 General Discussion Topics The general discussion forum with general topics
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 'ASK DOCTOR' Discussion Board The customized discussion board for doctors/specialist with customers.
--------- ------------------------------------- ----------------------------------------------------------------------------------
V CHAT ROOM
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Real Time Discussion between Real time general discussion with general topics.
customers, doctors, specialists,
and customers supports.
--------- ------------------------------------- ----------------------------------------------------------------------------------
VI REGISTRATION AND VALIDATION PROCESS
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Registration Page Customers need to register before log-in.
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 Log-in Page Customers need to log-in before proceeding.
--------- ------------------------------------- ----------------------------------------------------------------------------------
3 Validation Message (OK/Error) Error Message or OK Message after log-in.
--------- ------------------------------------- ----------------------------------------------------------------------------------
1
--------- ------------------------------------- ----------------------------------------------------------------------------------
VII EMAIL
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Mass automate mailing with certain RxAlternative can automate the mass mailing capability to certain customers or to
target the all customers in the database.
--------- ------------------------------------- ----------------------------------------------------------------------------------
VIII FEATURED PRODUCT DISPLAY Display the Feature Products in certain pages
--------- ------------------------------------- ----------------------------------------------------------------------------------
IX CONTENTS
--------- ------------------------------------- ----------------------------------------------------------------------------------
1 Article Library Contains Articles
--------- ------------------------------------- ----------------------------------------------------------------------------------
2 News Contains News
--------- ------------------------------------- ----------------------------------------------------------------------------------
3 Encyclopedia Contains Encyclopedia
--------- ------------------------------------- ----------------------------------------------------------------------------------
4 Books Library Contains Books Library
--------- ------------------------------------- ----------------------------------------------------------------------------------
X SURVEY Survey the customer preferences or other things based on the requirements
--------- ------------------------------------- ----------------------------------------------------------------------------------
XI CUSTOMER SUPPORT Using Forms, customers can contact customer support via email.
--------- ------------------------------------- ----------------------------------------------------------------------------------
XII REFERRAL The ability to insert new doctors/specialists into database, customer can search
the referrals based on their zip code.
--------- ------------------------------------- ----------------------------------------------------------------------------------
2
EXHIBIT B
FEES
In consideration of the Services, the Customer shall issue 750,000
shares (the "Shares") of the Customer's Common Stock to the Developer on a fully
diluted basis based on the number of shares issued and outstanding as of the
date of this Agreement which are approximately 20,000,000 shares. Therefore, the
Shares will represent 4.17% (four and seventeen hundredths percent =
750,000/20,000,000) of the Customer's outstanding common stock for dilution
purposes on the date this Agreement is signed and said equity position of 4.17%
shall be maintained at no additional cost to the Developer regardless of future
new issues of Common Stock or other diluting equity, until the sooner to occur
of (i) the Customer's Initial Public Offering (as defined below) or (ii) the
fifth anniversary of the date of this Agreement. (An "Initial Public Offering"
is any public offering of the Customer's common stock of at least ten million
(10,000,000) shares and/or resulting in a market capitalization of at least one
hundred million dollars ($100,000,000)).
The Customer is obligated to register the Shares in any registration
statement filed by the Customer with the Securities and Exchange Commission, so
that holders of the Shares shall be entitled to sell the same simultaneously
with and upon the terms and conditions as the securities sold for the account of
the Customer are being sold pursuant to any such registration statement, subject
to such lock-up provisions as may be proposed by the underwriter of said
registration statement and agreed to by the investors.
3
