OFFICE LEASE This Office Lease (this “Lease”), dated as of the date set forth in Section 1.1, is made by and between VII PAC SHORES INVESTORS, L.L.C., a Delaware limited liability company (“Landlord”), and BROADVISION, INC., a Delaware corporation...
This Office Lease (this “Lease”), dated as of the date set forth in Section 1.1, is made by and between VII PAC SHORES INVESTORS, L.L.C., a Delaware limited liability company (“Landlord”), and BROADVISION, INC., a Delaware corporation (“Tenant”). The following exhibits are incorporated herein and made a part hereof: Exhibit A (Outline of Premises); Exhibit B (Work Letter); Exhibit C (Form of Confirmation Letter); Exhibit D (Rules and Regulations); Exhibit E (Judicial Reference); Exhibit F (Additional Provisions); Exhibits G, G-1 and G-2 (Notice to Tenants and Transferees of Current or Future Uses of Adjacent Port Property); and Exhibit H (Notice to Pacific Shores Tenants, Lessees, Successors, Assigns And Transferees Regarding Current or Future Uses of Adjacent RMC Xxxxxxxx and Port of Redwood City Property).
1 BASIC LEASE INFORMATION
|
1.4“Base Rent”:
|
|||||
|
Period During
Term
|
Annual Base Rent Per Rentable Square Foot (rounded to the nearest 100th of a dollar)
|
Monthly Base Rent Per Rentable Square Foot (rounded to the nearest 100th of a dollar)
|
Monthly
Installment
of Base Rent
|
||
|
Commencement Date through last day of 12th full calendar month of Term
|
$36.60
|
||||
|
13th through 24th full calendar months of Term
|
$37.70
|
||||
|
25th full calendar month of Term through Expiration Date
|
$38.83
|
||||
Notwithstanding the foregoing, Tenant shall be entitled to an abatement of Base Rent, in the amount of $50,016.95 per month, for the first three and one-half calendar months of the Term. For the avoidance of doubt the parties acknowledge and agree that the total abated Base Rent shall be $175,059.33.
|
1.5“Additional Fees”:
|
Collectively, the Management Fee (defined below) and the Athletic Facility Fee (defined below). The term “Management Fee” shall mean a monthly fee equal to 3% of the Monthly Installment of Base Rent applicable to such month as described in Section 1.4 above (without taking into consideration any abatement of Base Rent for such month). The term “Athletic Facility Fee” shall mean a monthly fee equal to Tenant’s Share (defined below) of the product of (A) a fraction (the numerator of which is the Building Rentable Square Feet (defined below) and the denominator of which is 1,672,073 rentable square feet) multiplied by (B) the product of (i) the Monthly Base Rent Per Rentable Square Foot applicable to such month as described in Section 1.4 above (without taking into consideration any abatement of Base Rent for such month) multiplied by (ii) 38,000 rentable square fee.
|
|
1.6“Tenant’s Share”:
|
12.7598 % (based upon a total of 128,521 rentable square feet in the Building) (the “Building Rentable Square Feet”), subject to Section 2.1.1.
|
|
1.7“Permitted Use”:
|
General office use consistent with a first-class office building.
|
|
1.8.“Security Deposit”:
|
$75,000.00, as more particularly described in Section 21.
|
|
Prepaid Base Rent:
|
$50,016.95, as more particularly described in Section 3.
|
|
Prepaid Additional Rent:
|
$20,498.75, as more particularly described in Section 3.
|
|
1.9Parking:
|
48 unreserved parking spaces, at the rate of $00.00 per space per month, as such rate may be adjusted from time to time to reflect Landlord’s then current rates.
|
|
1.10Address of Tenant:
|
Before the Commencement Date:
0000 Xxxxxxx Xxxxxxxxx, Xxxxx 000
Xxxxxxx Xxxx, XX
From and after the Commencement Date: the Premises.
|
|
1.11Address of Landlord:
|
Equity Xxxxxx
0000 Xxxxxx Xxxxx, Xxxxx 000
Xxx Xxxxx, Xxxxxxxxxx 00000
Attn: Building manager
with copies to:
Equity Xxxxxx
0000 Xxxxxx Xxxxx, Xxxxx 000
Xxx Xxxxx, Xxxxxxxxxx 00000
Attn: Managing Counsel
and
Equity Xxxxxx
Xxx Xxxxx Xxxxxxxxx Xxxxx
Xxxxx 0000
Xxxxxxx, XX 00000
Attn: Lease Administration
|
|
1.12Broker(s):
|
Cornish & Xxxxx (“Tenant’s Broker”), representing Tenant, and Xxxxxxx Xxxxxx (“Landlord’s Broker”), representing Landlord.
|
|
1.13Building HVAC Hours and Holidays:
|
“Building HVAC Hours” means 7:00 a.m. to 6:00 p.m., Monday through Friday, excluding the day of observation of New Year’s Day, Presidents Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Christmas Day, and, at Landlord’s discretion, any other locally or nationally recognized holiday that is observed by other buildings comparable to and in the vicinity of the Building (collectively, “Holidays”).
|
|
1.14“Transfer Radius”:
|
None.
|
|
1.15“Tenant Improvements”:
|
Defined in Exhibit B, if any.
|
|
1.16“Guarantor”:
|
As of the date hereof, there is no Guarantor.
|
2 PREMISES AND COMMON AREAS.
2.1 The Premises.
2.1.1 Subject to the terms hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. Landlord and Tenant acknowledge that the rentable square footage of the Premises is as set forth in Section 1.2.2 and the rentable square footage of the Building is as set forth in Section 1.6; provided, however, that Landlord may from time to time re-measure the Premises and/or the Building in accordance with any generally accepted measurement standards selected by Landlord and adjust Tenant’s Share based on such re-measurement; provided further, however, that any such re-measurement shall not affect the amount of Base Rent payable for, or the amount of any tenant allowance applicable to, the initial Term. At any time Landlord may deliver to Tenant a notice substantially in the form of Exhibit C, as a confirmation of the information set forth therein. Tenant shall execute and return (or, by notice to Landlord, reasonably object to) such notice within five (5) days after receiving it, and if Tenant fails to do so, Tenant shall be deemed to have executed and returned it without exception.
2.1.2 Except as expressly provided herein, the Premises are accepted by Tenant in their configuration and condition existing on the date hereof (or in such other configuration and condition as any existing tenant of the Premises may cause to exist in accordance with its lease), without any obligation of Landlord to perform or pay for any alterations to the Premises, and without any representation or warranty regarding the configuration or condition of the Premises, the Building or the Project or their suitability for Tenant’s business.
2.2 Common Areas. Tenant may use, in common with Landlord and other parties and subject to the Rules and Regulations (defined in Exhibit D), any portions of the Property that are designated from time to time by Landlord for such use (the “Common Areas”).
3 RENT. Tenant shall pay all Base Rent and Additional Rent (defined below) (collectively, “Rent”) to Landlord or Landlord’s agent, without prior notice or demand or any setoff or deduction, at the place Landlord may designate from time to time, in money of the United States of America that, at the time of payment, is legal tender for the payment of all obligations. As used herein, “Additional Rent” means all amounts, other than Base Rent, that Tenant is required to pay Landlord hereunder. Monthly payments of Base Rent and monthly payments of Additional Fees, Additional Rent for Expenses (defined in Section 4.2.2), Taxes (defined in Section 4.2.3) and parking (collectively, “Monthly Rent”) shall be paid in advance on or before the first day of each calendar month during the Term; provided, however, that the installment of Base Rent for the first full calendar month for which Base Rent is payable hereunder and the installment of Additional Rent for Expenses and Taxes and Additional Fees for the first full calendar month for which such Additional Rent is payable hereunder shall be paid upon Tenant’s execution and delivery hereof. Except as otherwise provided herein, all other items of Additional Rent shall be paid within 30 days after Landlord’s request for payment. Rent for any partial calendar month shall be prorated based on the actual number of days in such month. Without limiting Landlord’s other rights or remedies, (a) if any installment of Rent is not received by Landlord or its designee within five (5) business days after its due date, Tenant shall pay Landlord a late charge equal to 5% of the overdue amount; and (b) any Rent that is not paid within 10 days after its due date shall bear interest, from its due date until paid, at the lesser of 18% per annum or the highest rate permitted by Law (defined in Section 5). Tenant’s covenant to pay Rent is independent of every other covenant herein.
4 EXPENSES AND TAXES.
4.1 General Terms. In addition to Base Rent, Tenant shall pay, in accordance with Section 4.4, for each Expense Year (defined in Section 4.2.1), an amount equal to the sum of (a) Tenant’s Share of Expenses for such Expense Year, plus (b) Tenant’s Share of Taxes for such Expense Year. Tenant’s Share of Expenses and Tenant’s Share of Taxes for any partial Expense Year shall be prorated based on the number of days in such Expense Year.
4.2 Definitions. As used herein, the following terms have the following meanings:
4.2.1 “Expense Year” means each calendar year in which any portion of the Term occurs.
4.2.2 “Expenses” means all expenses, costs and amounts that Landlord pays or accrues during any Expense Year because of or in connection with the ownership, management, maintenance, security, repair, replacement, restoration or operation of the Property. Landlord shall act in a reasonable manner in incurring Expenses. Expenses shall include (i) the cost of supplying all utilities, the cost of operating, repairing, maintaining and renovating the utility, telephone, mechanical, sanitary, storm-drainage, and elevator systems, and the cost of maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections, the cost of contesting any Laws that may affect Expenses, and the costs of complying with any governmentally-mandated transportation-management or similar program; (iii) the cost of all insurance premiums and deductibles; (iv) the cost of landscaping and relamping; (v) the cost of parking-area operation, repair, restoration, and maintenance; (vi) fees and costs, including consulting fees, legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Property; (vii) payments under any equipment-rental agreements and the fair rental value of any management office space; (viii) wages, salaries and other compensation, expenses and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security of the Property, and costs of training, uniforms, and employee enrichment for such persons; (ix) the costs of operation, repair, maintenance and replacement of all systems and equipment (and components thereof) of the Property; (x) the cost of janitorial, alarm, security and other services, replacement of wall and floor coverings, ceiling tiles and fixtures in Common Areas, maintenance and replacement of curbs and walkways, repair to roofs and re-roofing; (xi) rental or acquisition costs of supplies, tools, equipment, materials and personal property used in the maintenance, operation and repair of the Property; (xii) the cost of capital improvements or any other items that are (A) intended to effect economies in the operation or maintenance of the Property, reduce current or future Expenses, enhance the safety or security of the Property or its occupants, or enhance the environmental sustainability of the Property’s operations, (B) replacements or modifications of the nonstructural portions of the Base Building (defined in Section 7) or Common Areas that are required to keep the Base Building or Common Areas in good condition, or (C) required under any Law; (xiii) the cost of tenant-relation programs reasonably established by Landlord; and (xiv) payments or costs under any existing or future reciprocal easement agreement, transportation management agreement, landscape maintenance agreement, cost-sharing agreement or other covenant, condition, restriction or similar instrument affecting the Property.
Notwithstanding the foregoing, Expenses shall not include: (a) capital expenditures not described in clauses (xi) or (xii) above (in addition, any capital expenditure shall be amortized (including actual or imputed interest on the amortized cost) over such period of time as Landlord shall reasonably determine); (b) depreciation; (c) principal payments of mortgage or other non-operating debts of Landlord; (d) costs of repairs to the extent Landlord is reimbursed by insurance or condemnation proceeds; (e) except as provided in clause (xiii) above, costs of leasing space in the Building, including brokerage commissions, lease concessions, rental abatements and construction allowances granted to specific tenants; (f) costs of selling, financing or refinancing the Building; (g) fines, penalties or interest resulting from late payment of Taxes or Expenses; (h) organizational expenses of creating or operating the entity that constitutes Landlord; (i) damages paid to Tenant hereunder or to other tenants of the Building under their respective leases; and (j) that portion of any management fee paid to a manager of the Building which is based upon a percentage of the income generated from the Building (as distinguished from any expenses of such manager which are reimbursed by Landlord).
If, during any portion of any Expense Year, the Building is not 100% occupied (or a service provided by Landlord to tenants of the Building generally is not provided by Landlord to a tenant that provides such service itself, or any tenant of the Building is entitled to free rent, rent abatement or the like), Expenses for such Expense Year shall be determined as if the Building had been 100% occupied (and all services provided by Landlord to tenants of the Building generally had been provided by Landlord to all tenants, and no tenant of the Building had been entitled to free rent, rent abatement or the like) during such portion of such Expense Year.
4.2.3 “Taxes” means all federal, state, county or local governmental or municipal taxes, fees, charges, assessments, levies, licenses or other impositions, whether general, special, ordinary or extraordinary, that are paid or accrued during any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in connection with the ownership, leasing or operation of the Property, including, without limitation, those imposed by any improvement district or any community facilities district (including with respect to a district established for purposes of constructing the Seaport Boulevard improvements and other improvements as required in the development agreement related to the Project or by the City of Redwood City). Taxes shall include (a) real estate taxes; (b) general and special assessments; (c) transit taxes; (d) leasehold taxes; (e) personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems, appurtenances, furniture and other personal property used in connection with the Property; (f) any tax on the rent, right to rent or other income from any portion of the Property or as against the business of leasing any portion of the Property; and (g) any assessment, tax, fee, levy or charge imposed by any governmental agency, or by any non-governmental entity pursuant to any private cost-sharing agreement, in order to fund the provision or enhancement of any fire-protection, street-, sidewalk- or road-maintenance, refuse-removal or other service that is (or, before the enactment of Proposition 13, was) normally provided by governmental agencies to property owners or occupants without charge (other than through real property taxes). Any costs and expenses (including reasonable attorneys’ and consultants’ fees) incurred in attempting to protest, reduce or minimize Taxes shall be included in Taxes for the year in which they are incurred. Notwithstanding any contrary provision hereof, Taxes shall be determined without regard to any “green building” credit and shall exclude (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent (x) applicable to Landlord’s general or net income (as opposed to rents, receipts or income attributable to operations at the Property), or (y) measured solely by the square footage, rent, fees, services, tenant allowances or similar amounts, rights or obligations described or provided in or under any particular lease, license or similar agreement or transaction at the Building; (ii) any Expenses, and (iii) any items required to be paid or reimbursed by Tenant under Section 4.5.
4.3 Allocation. Landlord, in its reasonable discretion, may equitably allocate Expenses among office, retail or other portions or occupants of the Property. If Landlord incurs Expenses or Taxes for the Property together with another property (including, without limitation, the Athletic Facility), Landlord, in its reasonable discretion, shall equitably allocate such shared amounts between the Property and such other property.
4.4 Calculation and Payment of Expenses and Taxes.
4.4.1 Statement of Actual Expenses and Taxes; Payment by Tenant. Landlord shall endeavor to give to Tenant, after the end of each Expense Year, a statement (the “Statement”) setting forth the actual Expenses and Taxes for such Expense Year. If the amount paid by Tenant for such Expense Year pursuant to Section 4.4.2 is less or more than the sum of Tenant’s Share of the actual Expenses plus Tenant’s Share of the actual Taxes (as such amounts are set forth in such Statement), Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after delivery of such Statement. Any failure of Landlord to timely deliver the Statement for any Expense Year shall not diminish either party’s rights under this Section 4.
4.4.2 Statement of Estimated Expenses and Taxes. Landlord shall endeavor to give to Tenant, for each Expense Year, a statement (the “Estimate Statement”) setting forth Landlord’s reasonable estimates of the Expenses (the “Estimated Expenses”) and Taxes (the “Estimated Taxes”) for such Expense Year. Upon receiving an Estimate Statement, Tenant shall pay, with its next installment of Base Rent, an amount equal to the excess of (a) the amount obtained by multiplying (i) the sum of Tenant’s Share of the Estimated Expenses plus Tenant’s Share of the Estimated Taxes (as such amounts are set forth in such Estimate Statement), by (ii) a fraction, the numerator of which is the number of months that have elapsed in the applicable Expense Year (including the month of such payment) and the denominator of which is 12, over (b) any amount previously paid by Tenant for such Expense Year pursuant to this Section 4.4.2. Until Landlord delivers a new Estimate Statement (which Landlord may do at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the sum of Tenant’s Share of the Estimated Expenses plus Tenant’s Share of the Estimated Taxes, as such amounts are set forth in the previous Estimate Statement. Any failure of Landlord to timely deliver any Estimate Statement shall not diminish Landlord’s rights to receive payments and revise any previous Estimate Statement under this Section 4.
4.4.3 Retroactive Adjustment of Taxes. Notwithstanding any contrary provision hereof, if, after Landlord’s delivery of any Statement, an increase or decrease in Taxes occurs for the applicable Expense Year (whether by reason of reassessment, error, or otherwise), Taxes for such Expense Year shall be retroactively adjusted. If, as a result of such adjustment, it is determined that Tenant has under- or overpaid Tenant’s Share of such Taxes, Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after such adjustment is made.
4.5 Charges for Which Tenant Is Directly Responsible. Tenant shall pay, 10 days before delinquency, any taxes levied against Tenant’s equipment, furniture, fixtures and other personal property located in or about the Premises. If any such taxes are levied against Landlord or its property (or if the assessed value of Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or other personal property of Tenant), Landlord may pay such taxes (or such increased assessment) regardless of their (or its) validity, in which event Tenant, upon demand, shall repay to Landlord the amount so paid. If the Leasehold Improvements (defined in Section 7.1) are assessed for real property tax purposes at a valuation higher than the valuation at which tenant improvements conforming to Landlord’s “building standard” in other space in the Building are assessed, the Taxes levied against Landlord or the Property by reason of such excess assessed valuation shall be deemed taxes levied against Tenant’s personal property for purposes of this Section 4.5. Notwithstanding any contrary provision hereof, Tenant shall pay 10 days before delinquency (or reimburse to Landlord upon demand, if the same is required by Law to be paid by Landlord): (i) any rent tax, sales tax, service tax, transfer tax, value added tax, use tax, business tax, gross income tax, gross receipts tax, or other tax, assessment, fee, levy or charge measured solely by the square footage, Rent, services, tenant allowances or similar amounts, rights or obligations described or provided in or under this Lease; and (ii) any taxes assessed upon the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of any portion of the Property.
4.6 Books and Records. Within 60 days after receiving any Statement (the “Review Notice Period”), Tenant may give Landlord notice (“Review Notice”) stating that Tenant elects to review Landlord’s calculation of the Expenses and/or Taxes for the Expense Year to which such Statement applies and identifying with reasonable specificity the records of Landlord reasonably relating to such matters that Tenant desires to review. Within a reasonable time after receiving a timely Review Notice (and, at Landlord’s option, an executed confidentiality agreement as described below), Landlord shall deliver to Tenant, or make available for inspection at a location reasonably designated by Landlord, copies of such records. Within 60 days after such records are made available to Tenant (the “Objection Period”), Tenant may deliver to Landlord notice (an “Objection Notice”) stating with reasonable specificity any objections to the Statement, in which event Landlord and Tenant shall work together in good faith to resolve Tenant’s objections. Tenant may not deliver more than one Review Notice or more than one Objection Notice with respect to any Expense Year. If Tenant fails to give Landlord a Review Notice before the expiration of the Review Notice Period or fails to give Landlord an Objection Notice before the expiration of the Objection Period, Tenant shall be deemed to have approved the Statement. If Tenant retains an agent to review Landlord’s records, the agent must be with a CPA firm licensed to do business in the State of California and its fees shall not be contingent, in whole or in part, upon the outcome of the review. Tenant shall be responsible for all costs of such review. The records and any related information obtained from Landlord shall be treated as confidential, and as applicable only to the Premises, by Tenant, its auditors, consultants, and any other parties reviewing the same on behalf of Tenant (collectively, “Tenant’s Auditors”). Before making any records available for review, Landlord may require Tenant and Tenant’s Auditors to execute a reasonable confidentiality agreement, in which event Tenant shall cause the same to be executed and delivered to Landlord within 30 days after receiving it from Landlord, and if Tenant fails to do so, the Objection Period shall be reduced by one day for each day by which such execution and delivery follows the expiration of such 30-day period. Notwithstanding any contrary provision hereof, Tenant may not examine Landlord’s records or dispute any Statement if any Rent remains unpaid past its due date. If, for any Expense Year, Landlord and Tenant determine that the sum of Tenant’s Share of the actual Expenses plus Tenant’s Share of the actual Taxes is less or more than the amount reported, Tenant shall receive a credit in the amount of its overpayment against Rent then or next due hereunder, or pay Landlord the amount of its underpayment with the Rent next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Landlord shall pay Tenant the amount of its overpayment (less any Rent due), or Tenant shall pay Landlord the amount of its underpayment, within 30 days after such determination.
5 USE; COMPLIANCE WITH LAWS. Tenant shall not (a) use the Premises for any purpose other than the Permitted Use, or (b) do anything in or about the Premises that violates any of the Rules and Regulations, damages the reputation of the Project, interferes with, injures or annoys other occupants of the Project, or constitutes a nuisance. Tenant, at its expense, shall comply with all Laws relating to (i) the operation of its business at the Project, (ii) the use, condition, configuration or occupancy of the Premises, or (iii) the Building systems located in or exclusively serving the Premises. If, in order to comply with any such Law, Tenant must obtain or deliver any permit, certificate or other document evidencing such compliance, Tenant shall provide a copy of such document to Landlord promptly after obtaining or delivering it. If a change to any Common Area, the Building structure, or any Building system located outside of and not exclusively serving the Premises becomes required under Law (or if any such requirement is enforced) as a result of any Tenant-Insured Improvement (defined in Section 10.2.2), the installation of any trade fixture, or any particular use of the Premises (as distinguished from general office use), then Tenant, upon demand, shall (x) at Landlord’s option, either make such change at Tenant’s cost or pay Landlord the cost of making such change, and (y) pay Landlord a coordination fee equal to 10% of the cost of such change. As used herein, “Law” means any existing or future law, ordinance, regulation or requirement of any governmental authority having jurisdiction over the Project or the parties.
6 SERVICES.
6.1 Standard Services. Landlord shall provide the following services on all days (unless otherwise stated below): (a) subject to limitations imposed by Law, customary heating, ventilation and air conditioning (“HVAC”) in season during Building HVAC Hours; (b) electricity supplied by the applicable public utility, stubbed to the Premises; (c) water supplied by the applicable public utility (i) for use in lavatories and any drinking facilities located in Common Areas within the Building, and (ii) stubbed to the Building core for use in any plumbing fixtures located in the Premises; (d) janitorial services to the Building (other than the Premises), except on weekends and Holidays; and (e) elevator service (subject to scheduling by Landlord, and payment of Landlord’s standard usage fee, for any freight service).
6.2 Electricity Costs and Above-Standard Use. Electricity used by Tenant in the Premises shall, at Landlord’s option, be paid for by Tenant either: (a) through inclusion in Expenses (except as provided for excess usage); (b) by a separate charge payable by Tenant to Landlord; or (c) by separate charge billed by the applicable utility company and payable directly by Tenant. Tenant shall pay Landlord, upon billing, any costs of installing, operating and maintaining any equipment that is installed in order to measure electricity consumption in the Premises; and to the extent that Tenant is otherwise paying for consumption of electricity in the Premises through Expenses but Tenant’s consumption of electricity exceeds the rate Landlord reasonably deems to be standard for the Building, Tenant shall pay Landlord, upon billing, the cost of such excess consumption, including any costs of installing (to the extent not already installed), operating and maintaining any equipment that is installed in order to supply or measure such excess electricity. The connected electrical load of Tenant’s incidental-use equipment shall not exceed the Building-standard electrical design load, and Tenant’s electrical usage shall not exceed the capacity of the feeders to the Project or the risers or wiring installation. If Tenant’s consumption of water exceeds the rate Landlord reasonably deems to be standard for the Building, Tenant shall pay Landlord, upon billing, the cost of such excess consumption, including any costs of installing (to the extent not already installed), operating and maintaining any equipment that is installed in order to supply or measure such excess water. Landlord shall provide HVAC service outside Building HVAC Hours if Tenant gives Landlord such prior notice and pays Landlord such hourly cost per zone as Landlord may require; and, provided that, the minimum period of time for which Tenant may request HVAC service outside Building HVAC Hours is three (3) hours. Tenant shall not, without Landlord’s prior consent, use equipment that may affect the temperature maintained by the air conditioning system or consume above-Building-standard amounts of any water furnished for the Premises by Landlord pursuant to Section 6.1.
6.3 Interruption. Subject to Section 11, any failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if all or a material portion of the Premises is made untenantable or inaccessible for more than five (5) consecutive business days after notice from Tenant to Landlord by a Service Interruption that does not result from a Casualty (defined in Section 11) and that Landlord can correct through reasonable efforts, then, as Tenant’s sole remedy, Monthly Rent shall xxxxx for the period beginning on the day immediately following such 5-business-day period and ending on the day such Service Interruption ends, but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible.
7 REPAIRS AND ALTERATIONS.
7.1 Repairs. Subject to Section 11, Tenant, at its expense, shall perform all maintenance and repairs (including replacements) to the Premises, and keep the Premises in as good condition and repair as existed when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Tenant’s maintenance and repair obligations shall include (a) all leasehold improvements in the Premises, whenever and by whomever installed or paid for, including any Tenant Improvements, any Alterations (defined in Section 7.2), and any leasehold improvements installed pursuant to any prior lease, but excluding the Base Building (the “Leasehold Improvements”); (b) all supplemental heating, ventilation and air conditioning units, kitchens (including hot water heaters, dishwashers, garbage disposals, insta-hot dispensers, and plumbing) and similar facilities exclusively serving Tenant, whether located inside or outside of the Premises, and whenever and by whomever installed or paid for; (c) all Lines (defined in Section 23) and trade fixtures and (d) janitorial services to the Premises, except on weekends and Holidays, in a manner customarily performed within the janitorial industry in office buildings of similar age, size, class and composition as the Building in the Redwood City, California area, or such other reasonably comparable janitorial services designated in writing by Landlord from time to time. Notwithstanding the foregoing, Landlord may, at its option, perform such maintenance and repairs on Tenant’s behalf, in which case Tenant shall pay Landlord, upon demand, the cost of such work plus a coordination fee equal to 10% of such cost. Landlord shall perform all maintenance and repairs to (i) the roof and exterior walls and windows of the Building, (ii) the Base Building, and (iii) the Common Areas. As used herein, “Base Building” means the structural portions of the Building, together with all mechanical (including HVAC), electrical, plumbing and fire/life-safety systems serving the Building in general, whether located inside or outside of the Premises.
7.2 Alterations. Tenant may not make any improvement, alteration, addition or change to the Premises or to any mechanical, plumbing or HVAC facility or other system serving the Premises (an “Alteration”) without Landlord’s prior consent, which consent shall be requested by Tenant not less than 30 days before commencement of work and shall not be unreasonably withheld by Landlord. Notwithstanding the foregoing, Landlord’s prior consent shall not be required for any Alteration that is decorative only (e.g., carpet installation or painting) and not visible from outside the Premises, provided that Landlord receives 10 business days’ prior notice. For any Alteration, (a) Tenant, before commencing work, shall deliver to Landlord, and obtain Landlord’s approval of, plans and specifications; (b) Landlord, in its discretion, may require Tenant to obtain security for performance satisfactory to Landlord; (c) Tenant shall deliver to Landlord “as built” drawings (in CAD format, if requested by Landlord), completion affidavits, full and final lien waivers, and all governmental approvals; and (d) Tenant shall pay Landlord upon demand (i) Landlord’s reasonable out-of-pocket expenses incurred in reviewing the work, and (ii) a coordination fee equal to 10% of the cost of the work; provided, however, that this clause (d) shall not apply to any Tenant Improvements.
7.3 Tenant Work. Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
8 LANDLORD’S PROPERTY. All Leasehold Improvements shall become Landlord’s property upon installation and without compensation to Tenant. Notwithstanding the foregoing, if any Tenant-Insured Improvements are not, in Landlord’s reasonable judgment, Building-standard, then before the expiration or earlier termination hereof, Tenant shall, at Landlord’s election, either (a) at Tenant’s expense, and except as otherwise notified by Landlord, remove such Tenant-Insured Improvements, repair any resulting damage to the Premises or Building, and restore the affected portion of the Premises to its configuration and condition existing before the installation of such Tenant-Insured Improvements (or, at Landlord’s election, to a Building-standard tenant-improved configuration and condition as determined by Landlord), or (b) pay Landlord an amount equal to the estimated cost of such work, as reasonably determined by Landlord. If Tenant fails to timely perform any work required under clause (a) of the preceding sentence, Landlord may perform such work at Tenant’s expense.
9 LIENS. Tenant shall keep the Project free from any lien arising out of any work performed, material furnished or obligation incurred by or on behalf of Tenant. Tenant shall remove any such lien within 10 business days after notice from Landlord, and if Tenant fails to do so, Landlord, without limiting its remedies, may pay the amount necessary to cause such removal, whether or not such lien is valid. The amount so paid, together with reasonable attorneys’ fees and expenses, shall be reimbursed by Tenant upon demand.
10 INDEMNIFICATION; INSURANCE.
10.1 Waiver and Indemnification. Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the loss of use thereof), except to the extent such damage is caused by any gross negligence, willful misconduct or breach of this Lease of or by any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any cause in, on or about the Premises, or (b) occupancy of the Premises by, or any negligence, willful misconduct or breach of this Lease of or by, Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or invitees, except to the extent such Claim arises from any gross negligence, willful misconduct or breach of this Lease of or by any Landlord Party.
10.2 Tenant’s Insurance. Tenant shall maintain the following coverages in the following amounts:
10.2.1 Commercial General Liability Insurance covering claims of bodily injury, personal injury and property damage arising out of Tenant’s operations and contractual liabilities, including coverage formerly known as broad form, on an occurrence basis, with combined primary and excess/umbrella limits of $3,000,000 each occurrence and $4,000,000 annual aggregate.
10.2.2 Property Insurance covering (i) all office furniture, trade fixtures, office equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s property in the Premises installed by, for, or at the expense of Tenant, and (ii) any Leasehold Improvements installed by or for the benefit of Tenant, whether pursuant to this Lease or pursuant to any prior lease or other agreement to which Tenant was a party (“Tenant-Insured Improvements”). Such insurance shall be written on a special cause of loss form for physical loss or damage, for the full replacement cost value (subject to reasonable deductible amounts) new without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance, and shall include coverage for damage or other loss caused by fire or other peril, including vandalism and malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and providing business interruption coverage for a period of one year.
10.2.3 Workers’ Compensation statutory limits and Employers’ Liability limits of $1,000,000.
10.3 Form of Policies. The minimum limits of insurance required to be carried by Tenant shall not limit Tenant’s liability. Such insurance shall be issued by an insurance company that has an A.M. Best rating of not less than A-VIII and shall be in form and content reasonably acceptable to Landlord. Tenant’s Commercial General Liability Insurance shall (a) name the Landlord Parties and any other party designated by Landlord (“Additional Insured Parties”) as additional insureds; and (b) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and non-contributing with Tenant’s insurance. Landlord shall be designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements. Tenant shall deliver to Landlord, on or before the Commencement Date and at least 15 days before the expiration dates thereof, certificates from Tenant’s insurance company on the forms currently designated “XXXXX 25” (Certificate of Liability Insurance) and “XXXXX 28” (Evidence of Commercial Property Insurance) or the equivalent. Attached to the XXXXX 25 (or equivalent) there shall be an endorsement naming the Additional Insured Parties as additional insureds, and attached to the XXXXX 28 (or equivalent) there shall be an endorsement designating Landlord as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements, and each such endorsement shall be binding on Tenant’s insurance company. Upon Landlord’s request, Tenant shall deliver to Landlord, in lieu of such certificates, copies of the policies of insurance required to be carried under Section 10.2 showing that the Additional Insured Parties are named as additional insureds and that Landlord is designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements.
10.4 Subrogation. Each party waives, and shall cause its insurance carrier to waive, any right of recovery against the other party, any of its (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees or agents for any loss of or damage to property which loss or damage is (or, if the insurance required hereunder had been carried, would have been) covered by the waiving party’s property insurance. For purposes of this Section 10.4 only, (a) any deductible with respect to a party’s insurance shall be deemed covered by, and recoverable by such party under, valid and collectable policies of insurance, and (b) any contractor retained by Landlord to install, maintain or monitor a fire or security alarm for the Building shall be deemed an agent of Landlord.
10.5 Additional Insurance Obligations. Tenant shall maintain such increased amounts of the insurance required to be carried by Tenant under this Section 10, and such other types and amounts of insurance covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord, but not in excess of the amounts and types of insurance then being required by landlords of buildings comparable to and in the vicinity of the Building.
11 CASUALTY DAMAGE. With reasonable promptness after discovering any damage to the Premises (other than trade fixtures), or to any Common Area or Building system necessary for access to or tenantability of the Premises, resulting from any fire or other casualty (a “Casualty”), Landlord shall notify Tenant of Landlord’s reasonable estimate of the time required to substantially complete repair of such damage (the “Landlord Repairs”). If, according to such estimate, the Landlord Repairs cannot be substantially completed within 270 days after they are commenced, either party may terminate this Lease upon 60 days’ notice to the other party delivered within 10 days after Landlord’s delivery of such estimate. Within 90 days after discovering any damage to the Project resulting from any Casualty, Landlord may, whether or not the Premises are affected, terminate this Lease by notifying Tenant if (i) any Security Holder terminates any ground lease or requires that any insurance proceeds be used to pay any mortgage debt; (ii) any damage to Landlord’s property is not fully covered by Landlord’s insurance policies; (iii) Landlord decides to rebuild the Building or Common Areas so that it or they will be substantially different structurally or architecturally; (iv) the damage occurs during the last 12 months of the Term; or (v) any owner, other than Landlord, of any damaged portion of the Project does not intend to repair such damage. If this Lease is not terminated pursuant to this Section 11, Landlord shall promptly and diligently perform the Landlord Repairs, subject to reasonable delays for insurance adjustment and other events of Force Majeure. The Landlord Repairs shall restore the Premises (other than trade fixtures) and any Common Area or Building system necessary for access to or tenantability of the Premises to substantially the same condition that existed when the Casualty occurred, except for (a) any modifications required by Law or any Security Holder, and (b) any modifications to the Common Areas that are deemed desirable by Landlord, are consistent with the character of the Project, and do not materially impair access to or tenantability of the Premises. Notwithstanding Section 10.4, Tenant shall assign to Landlord (or its designee) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.2 with respect to any Tenant-Insured Improvements, and if the estimated or actual cost of restoring any Tenant-Insured Improvements exceeds the insurance proceeds received by Landlord from Tenant’s insurance carrier, Tenant shall pay such excess to Landlord within 15 days after Landlord’s demand. No Casualty and no restoration performed as required hereunder shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder; provided, however, that if the Premises (other than trade fixtures) or any Common Area or Building system necessary for access to or tenantability of the Premises is damaged by a Casualty, then, during any time that, as a result of such damage, any portion of the Premises is inaccessible or untenantable and is not occupied by Tenant, Monthly Rent shall be abated in proportion to the rentable square footage of such portion of the Premises.
12 NONWAIVER. No provision hereof shall be deemed waived by either party unless it is waived by such party expressly and in writing, and no waiver of any breach of any provision hereof shall be deemed a waiver of any subsequent breach of such provision or any other provision hereof. Landlord’s acceptance of Rent shall not be deemed a waiver of any preceding breach of any provision hereof, other than Tenant’s failure to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of such acceptance. No acceptance of payment of an amount less than the Rent due hereunder shall be deemed a waiver of Landlord’s right to receive the full amount of Rent due, whether or not any endorsement or statement accompanying such payment purports to effect an accord and satisfaction. No receipt of monies by Landlord from Tenant after the giving of any notice, the commencement of any suit, the issuance of any final judgment, or the termination hereof shall affect such notice, suit or judgment, or reinstate or extend the Term or Tenant’s right of possession hereunder.
13 CONDEMNATION. If any part of the Premises, Building or Project is taken for any public or quasi-public use by power of eminent domain or by private purchase in lieu thereof (a “Taking”) for more than 180 consecutive days, Landlord may terminate this Lease. If more than 25% of the rentable square footage of the Premises is Taken, or access to the Premises is substantially impaired as a result of a Taking, for more than 180 consecutive days, Tenant may terminate this Lease. Any such termination shall be effective as of the date possession must be surrendered to the authority, and the terminating party shall provide termination notice to the other party within 45 days after receiving written notice of such surrender date. Except as provided above in this Section 13, neither party may terminate this Lease as a result of a Taking. Tenant shall not assert any claim for compensation because of any Taking; provided, however, that Tenant may file a separate claim for any Taking of Tenant’s personal property or any fixtures that Tenant is entitled to remove upon the expiration hereof, and for moving expenses, so long as such claim does not diminish the award available to Landlord or any Security Holder and is payable separately to Tenant. If this Lease is terminated pursuant to this Section 13, all Rent shall be apportioned as of the date of such termination. If a Taking occurs and this Lease is not so terminated, Monthly Rent shall be abated for the period of such Taking in proportion to the percentage of the rentable square footage of the Premises, if any, that is subject to, or rendered inaccessible by, such Taking.
14 ASSIGNMENT AND SUBLETTING.
14.1 Transfers. Tenant shall not, without Landlord’s prior consent, assign, mortgage, pledge, hypothecate, encumber, permit any lien to attach to, or otherwise transfer this Lease or any interest hereunder, permit any assignment or other transfer hereof or any interest hereunder by operation of law, enter into any sublease or license agreement, otherwise permit the occupancy or use of any part of the Premises by any persons other than Tenant and its employees and contractors, or permit a Change of Control (defined in Section 14.6) to occur (each, a “Transfer”). If Tenant desires Landlord’s consent to any Transfer, Tenant shall provide Landlord with (i) notice of the terms of the proposed Transfer, including its proposed effective date (the “Contemplated Effective Date”), a description of the portion of the Premises to be transferred (the “Contemplated Transfer Space”), a calculation of the Transfer Premium (defined in Section 14.3), and a copy of all existing executed and/or proposed documentation pertaining to the proposed Transfer, and (ii) current financial statements of the proposed transferee (or, in the case of a Change of Control, of the proposed new controlling party(ies)) certified by an officer or owner thereof and any other information reasonably required by Landlord in order to evaluate the proposed Transfer (collectively, the “Transfer Notice”). Within 30 days after receiving the Transfer Notice, Landlord shall notify Tenant of (a) its consent to the proposed Transfer, (b) its refusal to consent to the proposed Transfer, or (c) its exercise of its rights under Section 14.4. Any Transfer made without Landlord’s prior consent shall, at Landlord’s option, be void and shall, at Landlord’s option, constitute a Default (defined in Section 19). Tenant shall pay Landlord a fee of $1,500.00 for Landlord’s review of any proposed Transfer, whether or not Landlord consents to it.
14.2 Landlord’s Consent. Subject to Section 14.4, Landlord shall not unreasonably withhold its consent to any proposed Transfer. Without limiting other reasonable grounds for withholding consent, it shall be deemed reasonable for Landlord to withhold its consent to a proposed Transfer if:
14.2.1 The proposed transferee is not a party of reasonable financial strength in light of the responsibilities to be undertaken in connection with the Transfer on the date the Transfer Notice is received; or
14.2.2 The proposed transferee has a character or reputation or is engaged in a business that is not consistent with the quality of the Building or the Project; or
14.2.3 The proposed transferee is a governmental entity or a nonprofit organization; or
14.2.4 In the case of a proposed sublease, license or other occupancy agreement, the rent or occupancy fee charged by Tenant to the transferee during the term of such agreement, calculated using a present value analysis, is less than 95% of the rent being quoted by Landlord or its Affiliate (defined in Section 14.8) at the time of such Transfer for comparable space in the Project for a comparable term, calculated using a present value analysis; or
14.2.5 The proposed transferee or any of its Affiliates, on the date the Transfer Notice is received, leases or occupies (or, at any time during the 6-month period ending on the date the Transfer Notice is received, has negotiated with Landlord or an Affiliate of Landlord to lease) space in the Project.
Notwithstanding any contrary provision hereof, (a) if Landlord consents to any Transfer pursuant to this Section 14.2 but Tenant does not enter into such Transfer within six (6) months thereafter, such consent shall no longer apply and such Transfer shall not be permitted unless Tenant again obtains Landlord’s consent thereto pursuant and subject to the terms of this Section 14; and (b) if Landlord unreasonably withholds its consent under this Section 14.2, Tenant’s sole remedies shall be contract damages (subject to Section 20) or specific performance, and Tenant waives all other remedies, including any right to terminate this Lease.
14.3 Transfer Premium. If Landlord consents to a Transfer, Tenant shall pay Landlord an amount equal to 75% of any Transfer Premium (defined below). As used herein, “Transfer Premium” means (a) in the case of an assignment, any consideration (including payment for Leasehold Improvements) paid by the assignee for such assignment; (b) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, the amount by which all rent and other consideration paid by the transferee to Tenant pursuant to such agreement exceeds the Monthly Rent payable by Tenant hereunder with respect to the Contemplated Transfer Space; and (c) in the case of a Change of Control, any consideration (including payment for Leasehold Improvements) paid by the new controlling party(ies) to the prior controlling party(ies) on account of this Lease. Payment of Landlord’s share of the Transfer Premium shall be made (x) in the case of an assignment or a Change of Control, within 10 days after Tenant or the prior controlling party(ies), as the case may be, receive(s) the consideration described above, and (y) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, within five (5) business days after Tenant receives the rent and other consideration described above.
14.4 Landlord’s Right to Recapture. Notwithstanding any contrary provision hereof, except in the case of a Permitted Transfer (defined in Section 14.8), Landlord, by notifying Tenant within 30 days after receiving the Transfer Notice, may terminate this Lease with respect to the Contemplated Transfer Space as of the Contemplated Effective Date. If the Contemplated Transfer Space is less than the entire Premises, then Base Rent, Tenant’s Share, and the number of parking spaces to which Tenant is entitled under Section 1.9 shall be deemed adjusted on the basis of the percentage of the rentable square footage of the portion of the Premises retained by Tenant. Upon request of either party, the parties shall execute a written agreement prepared by Landlord memorializing such termination.
14.5 Effect of Consent. If Landlord consents to a Transfer, (i) such consent shall not be deemed a consent to any further Transfer, (ii) Tenant shall deliver to Landlord, promptly after execution, an executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, and (iii) Tenant shall deliver to Landlord, upon Landlord’s request, a complete statement, certified by an independent CPA or Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium. In the case of an assignment, the assignee shall assume in writing, for Landlord’s benefit, all of Tenant’s obligations hereunder. No Transfer, with or without Landlord’s consent, shall relieve Tenant or any guarantor hereof from any liability hereunder. Notwithstanding any contrary provision hereof, Tenant, with or without Landlord’s consent, shall not enter into, or permit any party claiming by, through or under Tenant to enter into, any sublease, license or other occupancy agreement that provides for payment based in whole or in part on the net income or profit of the subtenant, licensee or other occupant thereunder.
14.6 Change of Control. As used herein, “Change of Control” means (a) if Tenant is a closely held professional service firm, the withdrawal or change (whether voluntary, involuntary or by operation of law) of more than 25% of its equity owners within a 12-month period; and (b) in all other cases, any transaction(s) resulting in the acquisition of a Controlling Interest (defined below) by one or more parties that did not own a Controlling Interest immediately before such transaction(s). As used herein, “Controlling Interest” means any direct or indirect equity or beneficial ownership interest in Tenant that confers upon its holder(s) the direct or indirect power to direct the ordinary management and policies of Tenant, whether through the ownership of voting securities, by contract or otherwise (but not through the ownership of voting securities listed on a recognized securities exchange).
14.7 Effect of Default. If Tenant is in Default, Landlord is irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any transferee under any sublease, license or other occupancy agreement to make all payments under such agreement directly to Landlord (which Landlord shall apply towards Tenant’s obligations hereunder) until such Default is cured. Such transferee shall rely upon any representation by Landlord that Tenant is in Default, whether or not confirmed by Tenant.
14.8 Permitted Transfers. Notwithstanding any contrary provision hereof, if Tenant is not in Default, Tenant may, without Landlord’s consent pursuant to Section 14.1, assign this Lease to (a) an Affiliate of Tenant (other than pursuant to a merger or consolidation), (b) a successor to Tenant by merger or consolidation, or (c) a successor to Tenant by purchase of all or substantially all of Tenant’s assets (a “Permitted Transfer”), provided that (i) at least 10 business days before the Transfer, Tenant notifies Landlord of such Transfer and delivers to Landlord any documents or information reasonably requested by Landlord relating thereto, including reasonable documentation that the Transfer satisfies the requirements of this Section 14.8; (ii) in the case of an assignment pursuant to clause (a) or (c) above, the assignee executes and delivers to Landlord, at least 10 business days before the assignment, a commercially reasonable instrument pursuant to which the assignee assumes, for Landlord’s benefit, all of Tenant’s obligations hereunder; (iii) in the case of an assignment pursuant to clause (b) above, (A) the successor entity has a net worth (as determined in accordance with GAAP, but excluding intellectual property and any other intangible assets (“Net Worth”)) immediately after the Transfer that is not less than the Net Worth of Tenant immediately before the Transfer, and (B) if Tenant is a closely held professional service firm, at least 75% of its equity owners existing 12 months before the Transfer are also equity owners of the successor entity; (iv) the transferee is qualified to conduct business in the State of California; and (v) the Transfer is made for a good faith operating business purpose and not in order to evade the requirements of this Section 14. As used herein, “Affiliate” means, with respect to any party, a person or entity that controls, is under common control with, or is controlled by such party.
15 SURRENDER. Upon the expiration or earlier termination hereof, and subject to Sections 8 and 11 and this Section 15, Tenant shall surrender possession of the Premises to Landlord in as good condition and repair as existed when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Before such expiration or termination, Tenant, without expense to Landlord, shall (a) remove from the Premises all debris and rubbish and all furniture, equipment, trade fixtures, Lines, free-standing cabinet work, movable partitions and other articles of personal property that are owned or placed in the Premises by Tenant or any party claiming by, through or under Tenant (except for any Lines not required to be removed under Section 23), and (b) repair all damage to the Premises and Building resulting from such removal. If Tenant fails to timely perform such removal and repair, Landlord may do so at Tenant’s expense (including storage costs). If Tenant fails to remove such property from the Premises, or from storage, within 30 days after notice from Landlord, any part of such property shall be deemed, at Landlord’s option, either (x) conveyed to Landlord without compensation, or (y) abandoned.
16 HOLDOVER. If Tenant fails to surrender the Premises upon the expiration or earlier termination hereof, Tenant’s tenancy shall be subject to the terms and conditions hereof; provided, however, that such tenancy shall be a tenancy at sufferance only, for the entire Premises, and Tenant shall pay Monthly Rent (on a per-month basis without reduction for any partial month) at a rate equal to twice the Monthly Rent applicable during the last calendar month of the Term. Nothing in this Section 16 shall limit Landlord’s rights or remedies or be deemed a consent to any holdover. If Landlord is unable to deliver possession of the Premises to a new tenant or to perform improvements for a new tenant as a result of Tenant’s holdover, Tenant shall be liable for all resulting damages, including lost profits, incurred by Landlord.
17 SUBORDINATION; ESTOPPEL CERTIFICATES. This Lease shall be subject and subordinate to all existing and future ground or underlying leases, mortgages, trust deeds and other encumbrances against the Building or Project, all renewals, extensions, modifications, consolidations and replacements thereof (each, a “Security Agreement”), and all advances made upon the security of such mortgages or trust deeds, unless in each case the holder of such Security Agreement (each, a “Security Holder”) requires in writing that this Lease be superior thereto. Upon any termination or foreclosure (or any delivery of a deed in lieu of foreclosure) of any Security Agreement, Tenant, upon request, shall attorn, without deduction or set-off, to the Security Holder or purchaser or any successor thereto and shall recognize such party as the lessor hereunder provided that such party agrees not to disturb Tenant’s occupancy so long as Tenant timely pays the Rent and otherwise performs its obligations hereunder. Within 10 days after request by Landlord, Tenant shall execute such further instruments as Landlord may reasonably deem necessary to evidence the subordination or superiority of this Lease to any Security Agreement. Tenant waives any right it may have under Law to terminate or otherwise adversely affect this Lease or Tenant’s obligations hereunder upon a foreclosure. Within 10 business days after Landlord’s request, Tenant shall execute and deliver to Landlord a commercially reasonable estoppel certificate in favor of such parties as Landlord may reasonably designate, including current and prospective Security Holders and prospective purchasers.
18 ENTRY BY LANDLORD. At all reasonable times and upon reasonable notice to Tenant, or in an emergency, Landlord may enter the Premises to (i) inspect the Premises; (ii) show the Premises to prospective purchasers, current or prospective Security Holders or insurers, or, during the last 12 months of the Term (or while an uncured Default exists), prospective tenants; (iii) post notices of non-responsibility; or (iv) perform maintenance, repairs or alterations. At any time and without notice to Tenant, Landlord may enter the Premises to perform required services. If reasonably necessary, Landlord may temporarily close any portion of the Premises to perform maintenance, repairs or alterations. In an emergency, Landlord may use any means it deems proper to open doors to and in the Premises. No entry into or closure of any portion of the Premises pursuant to this Section 18 shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder.
19 DEFAULTS; REMEDIES.
19.1 Events of Default. The occurrence of any of the following shall constitute a “Default”:
19.1.1 Any failure by Tenant to pay any Rent when due unless such failure is cured within five (5) business days after notice; or
19.1.2 Except where a specific time period is otherwise set forth for Tenant’s cure herein (in which event Tenant’s failure to cure within such time period shall be a Default), and except as otherwise provided in this Section 19.1, any breach by Tenant of any other provision hereof where such breach continues for 30 days after notice from Landlord; provided that if such breach cannot reasonably be cured within such 30-day period, Tenant shall not be in Default as a result of such breach if Tenant diligently commences such cure within such period, thereafter diligently pursues such cure, and completes such cure within 60 days after Landlord’s notice; or
19.1.3 Abandonment or vacation of all or a substantial portion of the Premises by Tenant; or
19.1.4 Any breach by Tenant of Sections 5, 14, 17 or 18 where such breach continues for more than two (2) business days after notice from Landlord; or
19.1.5 Tenant becomes in breach of Section 25.3.
If Tenant breaches a particular provision hereof (other than a provision requiring payment of Rent) on three (3) separate occasions during any 12-month period, Tenant’s subsequent breach of such provision shall be, at Landlord’s option, an incurable Default. The notice periods provided herein are in lieu of, and not in addition to, any notice periods provided by Law, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding.
19.2 Remedies Upon Default. Upon any Default, Landlord shall have, in addition to any other remedies available to Landlord at law or in equity (which shall be cumulative and nonexclusive), the option to pursue any one or more of the following remedies (which shall be cumulative and nonexclusive) without any notice or demand:
19.2.1 Landlord may terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy it may have for possession or arrearages in Rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following:
(a) The worth at the time of award of the unpaid Rent which has been earned at the time of such termination; plus
(b) The worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus
(c) The worth at the time of award of the amount by which the unpaid Rent for the balance of the Term after the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus
(d) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations hereunder or which in the ordinary course of things would be likely to result therefrom, including brokerage commissions, advertising expenses, expenses of remodeling any portion of the Premises for a new tenant (whether for the same or a different use), and any special concessions made to obtain a new tenant; plus
(e) At Landlord’s option, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by Law.
As used in Sections 19.2.1(a) and (b), the “worth at the time of award” shall be computed by allowing interest at a rate per annum equal to the lesser of (i) the annual “Bank Prime Loan” rate cited in the Federal Reserve Statistical Release Publication G.13(415), published on the first Tuesday of each calendar month (or such other comparable index as Landlord shall reasonably designate if such rate ceases to be published) plus two (2) percentage points, or (ii) the highest rate permitted by Law. As used in Section 19.2.1(c), the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.
19.2.2 Landlord shall have the remedy described in California Civil Code § 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover Rent as it becomes due, if lessee has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.
19.2.3 Landlord shall at all times have the rights and remedies (which shall be cumulative with each other and cumulative and in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2, or any Law or other provision hereof), without prior demand or notice except as required by Law, to seek any declaratory, injunctive or other equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof.
19.3 Efforts to Relet. Unless Landlord provides Tenant with express notice to the contrary, no re-entry, repossession, repair, maintenance, change, alteration, addition, reletting, appointment of a receiver or other action or omission by Landlord shall (a) be construed as an election by Landlord to terminate this Lease or Tenant’s right to possession, or to accept a surrender of the Premises, or (b) operate to release Tenant from any of its obligations hereunder. Tenant waives, for Tenant and for all those claiming by, through or under Tenant, California Civil Code § 3275 and California Code of Civil Procedure §§ 1174(c) and 1179 and any existing or future rights to redeem or reinstate, by order or judgment of any court or by any legal process or writ, this Lease or Tenant’s right of occupancy of the Premises after any termination hereof.
19.4 Landlord Default. Landlord shall not be in default hereunder unless it fails to begin within 30 days after notice from Tenant, or fails to pursue with reasonable diligence thereafter, the cure of any breach by Landlord of its obligations hereunder. Before exercising any remedies for a default by Landlord, Tenant shall give notice and a reasonable time to cure to any Security Holder of which Tenant has been notified.
20 LANDLORD EXCULPATION. Notwithstanding any contrary provision hereof, (a) the liability of the Landlord Parties to Tenant shall be limited to an amount equal to the lesser of (i) Landlord’s interest in the Building, or (ii) the equity interest Landlord would have in the Building if the Building were encumbered by third-party debt in an amount equal to 80% of the value of the Building (as such value is determined by Landlord); (b) Tenant shall look solely to Landlord’s interest in the Building for the recovery of any judgment or award against any Landlord Party; (c) no Landlord Party shall have any personal liability for any judgment or deficiency, and Tenant waives and releases such personal liability on behalf of itself and all parties claiming by, through or under Tenant; and (d) no Landlord Party shall be liable for any injury or damage to, or interference with, Tenant’s business, including loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, or for any form of special or consequential damage.
21 SECURITY DEPOSIT. Concurrently with its execution and delivery hereof, Tenant shall deposit with Landlord the Security Deposit, if any, as security for Tenant’s performance of its obligations hereunder. If Tenant breaches any provision hereof, Landlord may, at its option, without notice to Tenant, apply all or part of the Security Deposit to pay any past-due Rent, cure any breach by Tenant, or compensate Landlord for any other loss or damage caused by such breach. If Landlord so applies any portion of the Security Deposit, Tenant, within three (3) days after demand therefor, shall restore the Security Deposit to its original amount. The Security Deposit is not an advance payment of Rent or measure of damages. Any unapplied portion of the Security Deposit shall be returned to Tenant within 60 days after the latest to occur of (a) the expiration of the Term, (b) Tenant’s surrender of the Premises as required hereunder, or (c) determination of the final Rent due from Tenant. Landlord shall not be required to keep the Security Deposit separate from its other accounts.
22 RELOCATION. Landlord, after giving notice, may move Tenant to other space in the Project comparable in size and utility to the Premises. In such event, all terms hereof shall apply to the new space, except that Base Rent and Tenant’s Share shall not increase as a result of such relocation. Landlord, at its expense, shall provide Tenant with tenant improvements in the new space at least equal in quality to those in the Premises. Landlord shall reimburse Tenant for Tenant’s reasonable moving, re-cabling and stationery-replacement costs. The parties shall execute a written agreement prepared by Landlord memorializing the relocation.
23 COMMUNICATIONS AND COMPUTER LINES. All Lines installed pursuant to this Lease shall be (a) installed in accordance with Section 7; and (b) clearly marked with adhesive plastic labels (or plastic tags attached to such Lines with wire) to show Tenant’s name, suite number, and the purpose of such Lines (i) every six (6) feet outside the Premises (including the electrical room risers and any Common Areas), and (ii) at their termination points. Landlord may designate specific contractors for work relating to vertical Lines. Sufficient spare cables and space for additional cables shall be maintained for other occupants, as reasonably determined by Landlord. Unless otherwise notified by Landlord, Tenant, at its expense and before the expiration or earlier termination hereof, shall remove all Lines and repair any resulting damage. As used herein, “Lines” means all communications or computer wires and cables serving the Premises, whenever and by whomever installed or paid for, including any such wires or cables installed pursuant to any prior lease.
24 PARKING. Tenant may park in the Building’s parking facilities (the “Parking Facility”), in common with other parties, upon the following terms and conditions. Tenant shall not use more than the number of unreserved and/or reserved parking spaces set forth in Section 1.9. Tenant shall pay Landlord, in accordance with Section 3, any fees for the parking spaces described in Section 1.9. Tenant shall pay Landlord any fees, taxes or other charges imposed by any governmental or quasi-governmental agency in connection with the Parking Facility, to the extent such amounts are allocated to Tenant by Landlord. Landlord shall not be liable to Tenant, nor shall this Lease be affected, if any parking is impaired by (or any parking charges are imposed as a result of) any Law. Tenant shall comply with all rules and regulations established by Landlord from time to time for the orderly operation and use of the Parking Facility, including any sticker or other identification system and the prohibition of vehicle repair and maintenance activities in the Parking Facility. Landlord may, in its discretion, allocate and assign parking passes among Tenant and the other tenants in the Building. Tenant’s use of the Parking Facility shall be at Tenant’s sole risk, and Landlord shall have no liability for any personal injury or damage to or theft of any vehicles or other property occurring in the Parking Facility or otherwise in connection with any use of the Parking Facility by Tenant or its employees or invitees. Landlord may alter the size, configuration, design, layout or any other aspect of the Parking Facility, and, in connection therewith, temporarily deny or restrict access to the Parking Facility, in each case without abatement of Rent or liability to Tenant. Landlord may delegate its responsibilities hereunder to a parking operator, in which case (i) such parking operator shall have all the rights of control reserved herein by Landlord, (ii) Tenant shall enter into a parking agreement with such parking operator, (iii) Tenant shall pay such parking operator, rather than Landlord, any charge established hereunder for the parking spaces, and (iv) Landlord shall have no liability for claims arising through acts or omissions of such parking operator except to the extent caused by Landlord’s gross negligence or willful misconduct. Tenant’s parking rights under this Section 24 are solely for the benefit of Tenant’s employees and invitees and such rights may not be transferred without Landlord’s prior consent, except pursuant to a Transfer permitted under Section 14.
25 MISCELLANEOUS.
25.1 Notices. No notice, demand, statement, designation, request, consent, approval, election or other communication given hereunder (“Notice”) shall be binding upon either party unless (a) it is in writing; (b) it is (i) sent by certified or registered mail, postage prepaid, return receipt requested, (ii) delivered by a nationally recognized courier service, or (iii) delivered personally; and (c) it is sent or delivered to the address set forth in Section 1.10 or 1.11, as applicable, or to such other place (other than a P.O. box) as the recipient may from time to time designate in a Notice to the other party. Any Notice shall be deemed received on the earlier of the date of actual delivery or the date on which delivery is refused, or, if Tenant is the recipient and has vacated its notice address without providing a new notice address, three (3) days after the date the Notice is deposited in the U.S. mail or with a courier service as described above.
25.2 Force Majeure. If either party is prevented from performing any obligation hereunder by any strike, act of God, war, terrorist act, shortage of labor or materials, governmental action, civil commotion or other cause beyond such party’s reasonable control (“Force Majeure”), such obligation shall be excused during (and any time period for the performance of such obligation shall be extended by) the period of such prevention; provided, however, that this Section 25.2 shall not (a) permit Tenant to hold over in the Premises after the expiration or earlier termination hereof, or (b) excuse any of Tenant’s obligations under Sections 3, 4, 5, 21 or 25.3 or any of Tenant’s obligations whose nonperformance would interfere with another occupant’s use, occupancy or enjoyment of its premises or the Project.
25.3 Representations and Covenants. Tenant represents, warrants and covenants that (a) Tenant is, and at all times during the Term will remain, duly organized, validly existing and in good standing under the Laws of the state of its formation and qualified to do business in the state of California; (b) neither Tenant’s execution of nor its performance under this Lease will cause Tenant to be in violation of any agreement or Law; (c) Tenant (and any guarantor hereof) has not, and at no time during the Term will have, (i) made a general assignment for the benefit of creditors, (ii) filed a voluntary petition in bankruptcy or suffered the filing of an involuntary petition by creditors, (iii) suffered the appointment of a receiver to take possession of all or substantially all of its assets, (iv) suffered the attachment or other judicial seizure of all or substantially all of its assets, (v) admitted in writing its inability to pay its debts as they come due, or (vi) made an offer of settlement, extension or composition to its creditors generally; and (d) no party that (other than through the passive ownership of interests traded on a recognized securities exchange) constitutes, owns, controls, or is owned or controlled by Tenant, any guarantor hereof or any subtenant of Tenant is, or any time during the Term will be, (i) in violation of any Laws relating to terrorism or money laundering, or (ii) among the parties identified on any list compiled pursuant to Executive Order 13224 for the purpose of identifying suspected terrorists or on the most current list published by the U.S. Treasury Department Office of Foreign Assets Control at its official website, xxxx://xxx.xxxxx.xxx/xxxx/xxxxxx.xxx or any replacement website or other replacement official publication of such list.
25.4 Signs. Landlord shall include Tenant’s name in any tenant directory located in the lobby on the first floor of the Building. If any part of the Premises is located on a multi-tenant floor, Landlord, at Tenant’s cost, shall provide identifying suite signage for Tenant comparable to that provided by Landlord on similar floors in the Building. Tenant may not install (a) any signs outside the Premises, or (b) without Landlord’s prior consent in its sole and absolute discretion, any signs, window coverings, blinds or similar items that are visible from outside the Premises.
25.5 Supplemental HVAC. If any supplemental HVAC unit (a “Unit”) serves the Premises, then (a) Tenant shall pay the costs of all electricity consumed in the Unit’s operation, together with the cost of installing a meter to measure such consumption; (b) Tenant, at its expense, shall (i) operate and maintain the Unit in compliance with all applicable Laws and such reasonable rules and procedures as Landlord may impose; (ii) keep the Unit in as good working order and condition as exists upon its installation (or, if later, on the date Tenant takes possession of the Premises), subject to normal wear and tear and damage resulting from Casualty; (iii) maintain in effect, with a contractor reasonably approved by Landlord, a contract for the maintenance and repair of the Unit, which contract shall require the contractor, at least once every three (3) months, to inspect the Unit and provide to Tenant a report of any defective conditions, together with any recommendations for maintenance, repair or parts-replacement; (iv) follow all reasonable recommendation of such contractor; and (v) promptly provide to Landlord a copy of such contract and each report issued thereunder; (c) the Unit shall become Landlord’s property upon installation and without compensation to Tenant; provided, however, that upon Landlord’s request at the expiration or earlier termination hereof, Tenant, at its expense, shall remove the Unit and repair any resulting damage; (d) the Unit shall be deemed (i) a Leasehold Improvement (except for purposes of Section 8), and (ii) for purposes of Section 11, part of the Premises; (e) if the Unit exists on the date of mutual execution and delivery hereof, Tenant accepts the Unit in its “as is” condition, without representation or warranty as to quality, condition, fitness for use or any other matter; (f) if the Unit connects to the Building’s condenser water loop (if any), then Tenant shall pay to Landlord, as Additional Rent, Landlord’s standard one-time fee for such connection and Landlord’s standard monthly per-ton usage fee; and (g) if any portion of the Unit is located on the roof, then (i) Tenant’s access to the roof shall be subject to such reasonable rules and procedures as Landlord may impose; (ii) Tenant shall maintain the affected portion of the roof in a clean and orderly condition and shall not interfere with use of the roof by Landlord or any other tenants or licensees; and (iii) Landlord may relocate the Unit and/or temporarily interrupt its operation, without liability to Tenant, as reasonably necessary to maintain and repair the roof or otherwise operate the Building.
25.6 Attorneys’ Fees. In any action or proceeding between the parties, including any appellate or alternative dispute resolution proceeding, the prevailing party may recover from the other party all of its costs and expenses in connection therewith, including reasonable attorneys’ fees and costs. Tenant shall pay all reasonable attorneys’ fees and other fees and costs that Landlord incurs in interpreting or enforcing this Lease or otherwise protecting its rights hereunder (a) where Tenant has failed to pay Rent when due, or (b) in any bankruptcy case, assignment for the benefit of creditors, or other insolvency, liquidation or reorganization proceeding involving Tenant or this Lease.
25.7 Brokers. Tenant represents to Landlord that it has dealt only with Tenant’s Broker as its broker in connection with this Lease. Tenant shall indemnify, defend, and hold Landlord harmless from all claims of any brokers, other than Tenant’s Broker, claiming to have represented Tenant in connection with this Lease. Landlord shall indemnify, defend and hold Tenant harmless from all claims of any brokers, including Landlord’s Broker, claiming to have represented Landlord in connection with this Lease. Tenant acknowledges that any Affiliate of Landlord that is involved in the negotiation of this Lease is representing only Landlord, and that any assistance rendered by any agent or employee of such Affiliate in connection with this Lease or any subsequent amendment or other document related hereto has been or will be rendered as an accommodation to Tenant solely in furtherance of consummating the transaction on behalf of Landlord, and not as agent for Tenant.
25.8 Governing Law; WAIVER OF TRIAL BY JURY. This Lease shall be construed and enforced in accordance with the Laws of the State of California. THE PARTIES WAIVE, TO THE FULLEST EXTENT PERMITTED BY LAW, THE RIGHT TO TRIAL BY JURY IN ANY LITIGATION ARISING OUT OF OR RELATING TO THIS LEASE, THE RELATIONSHIP OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE OR ANY EMERGENCY OR STATUTORY REMEDY.
25.9 Waiver of Statutory Provisions. Each party waives California Civil Code §§ 1932(2) and 1933(4). Tenant waives (a) any rights under (i) California Civil Code §§ 1932(1), 1941, 1942, 1950.7 or any similar Law, or (ii) California Code of Civil Procedure § 1265.130; and (b) any right to terminate this Lease under California Civil Code § 1995.310.
25.10 Interpretation. As used herein, the capitalized term “Section” refers to a section hereof unless otherwise specifically provided herein. As used in this Lease, the terms “herein,” “hereof,” “hereto” and “hereunder” refer to this Lease and the term “include” and its derivatives are not limiting. Any reference herein to “any part” or “any portion” of the Premises, the Property or any other property shall be construed to refer to all or any part of such property. Wherever this Lease requires Tenant to comply with any Law, rule, regulation, procedure or other requirement or prohibits Tenant from engaging in any particular conduct, this Lease shall be deemed also to require Tenant to cause each of its employees, licensees, invitees and subtenants, and any other party claiming by, through or under Tenant, to comply with such requirement or refrain from engaging in such conduct, as the case may be. Wherever this Lease requires Landlord to provide a customary service or to act in a reasonable manner (whether in incurring an expense, establishing a rule or regulation, providing an approval or consent, or performing any other act), this Lease shall be deemed also to provide that whether such service is customary or such conduct is reasonable shall be determined by reference to the practices of owners of buildings that (i) are comparable to the Building in size, age, class, quality and location, and (ii) at Landlord’s option, have been, or are being prepared to be, certified under the U.S. Green Building Council’s Leadership in Energy and Environmental Design (LEED) rating system or a similar rating system. Tenant waives the benefit of any rule that a written agreement shall be construed against the drafting party.
25.11 Entire Agreement. This Lease sets forth the entire agreement between the parties relating to the subject matter hereof and supersedes any previous agreements (none of which shall be used to interpret this Lease). Tenant acknowledges that in entering into this Lease it has not relied upon any representation, warranty or statement, whether oral or written, not expressly set forth herein. This Lease can be modified only by a written agreement signed by both parties.
25.12 Other. Landlord, at its option, may cure any Default, without waiving any right or remedy or releasing Tenant from any obligation, in which event Tenant shall pay Landlord, upon demand, the cost of such cure. If any provision hereof is void or unenforceable, no other provision shall be affected. Submission of this instrument for examination or signature by Tenant does not constitute an option or offer to lease, and this instrument is not binding until it has been executed and delivered by both parties. If Tenant is comprised of two or more parties, their obligations shall be joint and several. Time is of the essence with respect to the performance of every provision hereof in which time of performance is a factor. So long as Tenant performs its obligations hereunder, Tenant shall have peaceful and quiet possession of the Premises against any party claiming by, through or under Landlord, subject to the terms hereof. Landlord may transfer its interest herein, in which event Landlord shall be released from, Tenant shall look solely to the transferee for the performance of, and the transferee shall be deemed to have assumed, all of Landlord’s obligations arising hereunder after the date of such transfer (including the return of any Security Deposit) and Tenant shall attorn to the transferee. Landlord reserves all rights not expressly granted to Tenant hereunder, including the right to make alterations to the Project. No rights to any view or to light or air over any property are granted to Tenant hereunder. Landlord reserves to itself the right, from time to time, to grant such easements, rights and dedications that Landlord deems necessary or desirable, and to cause the recordation of Parcel Maps and conditions, covenants and restrictions, so long as such easements, rights, dedications, Parcel Maps and conditions, covenants and restrictions do not unreasonably interfere with Tenant’s rights hereunder to use of the Premises, the Common Area or the Parking Facility, including access thereto. Upon 10 days prior written request, Tenant shall sign any such documents, and take such other actions, which are reasonably necessary or appropriate to accomplish such granting, recordation and subordination of this Lease to same. The expiration or termination hereof shall not relieve either party of any obligation that accrued before, or continues to accrue after, such expiration or termination.
25.13 Athletic Facility. Subject to the provisions of this Section 25.13, Landlord shall provide Tenant with 62 memberships to the athletic facility located at 0000 Xxxxxxx Xxxxxxxxx, Xxxxxxx Xxxx, Xxxxxxxxxx (the “Athletic Facility”). Such memberships shall be for the non-exclusive use of the Athletic Facility by Tenant’s employees during the Term of the Lease. Any Tenant employee electing to use one of the memberships and the Athletic Facility first shall execute and deliver to Landlord (or the owner or operator of such Athletic Facility) Landlord’s (or such owner’s or operator’s) then-standard form of license or other agreement governing such use. The use of the Athletic Facility shall be subject to the reasonable rules and regulations (including rules regarding hours of use) established from time to time by Landlord (or the owner or operator of such Athletic Facility). Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any Claim that is imposed or asserted by any third party and arises from (a) any negligence or willful misconduct of Tenant’s employee(s) in connection with the use of the Athletic Facility, or (b) any breach by Tenant’s employee(s) of any representation, covenant or other term contained in the license or other agreement governing such employee’s use of the Athletic Facility. The costs of operating, maintaining and repairing the Athletic Facility shall be included as part of Expenses, subject to the terms and conditions of Section 4.
25.14 Project Declaration. The parties acknowledge that (a) all provisions of this Lease are subject and subordinate to the terms of the Project Declaration (defined below), and (b) under the Project Declaration, the Declarant (as defined in the Project Declaration) or the Association (as defined in the Project Declaration) is responsible, by itself or through the Manager (as defined in the Project Declaration), for maintaining, repairing, replacing, restoring, operating and maintaining (“Operating”) the Project Common Areas (defined below) on the terms and conditions of, and subject to the allocation and assessment of costs incurred as provided in, the Project Declaration. Accordingly, the parties agree that, notwithstanding any contrary provision in the Lease, (i) Tenant’s rights hereunder are subject and subordinate to the terms of the Project Declaration, (ii) to the extent the Landlord is no longer the Declarant nor the Manager (or to the extent the Project Common Areas are owned or Operated by the Association), Landlord’s obligations hereunder to provide Tenant (or Tenant’s employees) with rights to use the Project Common Areas shall be limited to the obligation to use commercially reasonable efforts to enforce the obligations of such parties under the Project Declaration to provide Tenant (or Tenant’s employees) with such rights; (iii) to the extent the Landlord is no longer the Declarant nor the Manager (or to the extent the Project Common Areas are owned or Operated by the Association), Landlord’s obligations hereunder to Operate the Project Common Areas as described herein shall be limited to the obligations to (A) use commercially reasonable efforts to enforce the obligations of such parties under the Project Declaration to so Operate the Project Common Areas, and (B) perform any obligations to so Operate the Project Common Areas that Landlord may have under the Project Declaration; and (iv) all “Assessments” (as defined in the Project Declaration) attributable to the Property shall be included in Expenses, subject to the terms and conditions of Section 4. Landlord shall have no liability for claims arising from acts or omissions of the Association nor, to the extent the Landlord is no longer the Declarant nor the Manager, for the acts or omissions of any such parties. Without limiting the foregoing, Landlord shall not be liable to Tenant, and Tenant shall not be entitled to any abatement of Rent, as a result of a person or entity exercising its rights under the Project Declaration. Tenant shall not breach, nor cause the Landlord to be in breach of, the terms of the Project Declaration. Without limitation, Tenant, at its sole cost and expense, shall comply with the following terms of the Project Declaration to the extent applicable to the Tenant’s use and occupancy of the Premises and/or Tenant’s use of the Building or Project Common Areas: Sections 6.2, 6.3, 6.4, 7.1, 7.3, 7.4, 7.6, 7.10, 7.11, 7.12, 7.13, 7.14, 7.15, 7.16, 7.17, 7.18 and 7.19; provided, however, that Tenant shall not submit any plans for approval by the Committee (as defined in the Project Declaration) without the prior written consent of Landlord. As used herein, “Project Common Areas” means the areas defined in the Project Declaration as “Common Areas.” As used herein, “Project Declaration” means that certain Declaration of Covenants, Conditions, Restrictions, Easements and Charges for Commercial Planned Development dated June 9, 2000 and recorded July 21, 2000 as Instrument No. 2000-089122 in the Official Records of the County of San Mateo, California, as amended by (1) that certain First Amendment to Declaration of Covenants, Conditions, Restrictions, Easements and Charges for Commercial Planned Development dated as of December 6, 2006 and recorded December 7, 2006 as Instrument No. 2006-185322 in the Official Records of the County of San Mateo, California and (2) that certain Second Amendment to Declaration of Covenants, Conditions, Restrictions, Easements and Charges for Commercial Planned Development dated as of April __, 2007 and recorded April 11, 2007 as Instrument No. 2007-055324 in the Official Records of the County of San Mateo, California.
25.15 Underlying Documents. Tenant agrees that (i) other than with respect to the Project Declaration and the Security Agreement (which documents are addressed elsewhere in this Lease), Tenant’s rights under this Lease are subject and subordinate to any covenants, conditions restrictions and other documents of record applicable to the Project (the “Underlying Documents”), (ii) Tenant shall not cause Landlord to be in breach of the Underlying Documents and (iii) to the extent applicable to Tenant’s use and occupancy of the Premises and/or Tenant’s use of the Building and the Common Areas, Tenant shall comply with the terms of the Underlying Documents at its sole cost and expense.
[SIGNATURES ARE ON THE FOLLOWING PAGE]
IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and date first above written.
LANDLORD:
VII PAC SHORES INVESTORS, L.L.C., a Delaware limited liability company
By: VII PAC SHORES JUNIOR MEZZ, L.L.C., a Delaware limited liability company
its sole member and manager
By: BREP/SCG PAC SHORES HOLDINGS LLC
a Delaware limited liability company, its sole member and manager
By: BREP HOLDINGS PS L.L.C., a Delaware limited liability company
its member
By:
Name:
Title:
By: PS VII HOLDINGS, LLC, a Delaware limited liability company
its member
By:
Name:
Title:
TENANT:
BROADVISION, INC., a Delaware corporation
By:
Name:
Title:
[chairman][president][vice-president]
By:
Name:
Title:
|
|
[secretary][assistant secretary][chief
|
financial officer][assistant treasurer]
PACIFIC SHORES CENTER – BUILDING NUMBER 5
OUTLINE OF PREMISES
See Attached
Exhibit A
PACIFIC SHORES CENTER – BUILDING NUMBER 5
WORK LETTER
As used in this Exhibit B (this “Work Letter”), the following terms shall have the following meanings: “Agreement” means the lease of which this Work Letter is a part. “Tenant Improvements” means all improvements to be constructed in the Premises pursuant to this Work Letter. “Tenant Improvement Work” means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
|
1
|
ALLOWANCE.
|
1.1 Allowance. Tenant shall be entitled to a one-time tenant improvement allowance (the “Allowance”) in the amount of $10.00 per rentable square foot of the Premises to be applied toward (a) the Allowance Items (defined in Section 1.2 below) and (b) the reasonable costs of purchasing Tenant’s furniture, equipment and/or other personal property for the Premises (not to exceed $2.00 per rentable square foot of the Premises), as more fully provided in Section 3 of the Exhibit F. Tenant shall be responsible for all costs associated with the Tenant Improvement Work, including the costs of the Allowance Items, to the extent such costs exceed the lesser of (a) the Allowance, or (b) the aggregate amount that Landlord is required to disburse for such purpose pursuant to this Work Letter. Notwithstanding any contrary provision of this Agreement, if Tenant fails to use the entire Allowance within one (1) year following the Commencement Date, the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto.
1.2 Disbursement of the Allowance. Except as otherwise provided in this Work Letter, the Allowance shall be disbursed by Landlord only for the following items (the “Allowance Items”): (a) [Intentionally Omitted]; (b) plan-check, permit and license fees relating to performance of the Tenant Improvement Work; (c) the cost of performing the Tenant Improvement Work, including after hours charges, testing and inspection costs, freight elevator usage, hoisting and trash removal costs, and contractors’ fees and general conditions; (d) the cost of any change to the base, shell or core of the Premises or Building required by the Work List (defined in Section 2.1 below) (including if such change is due to the fact that such work is prepared on an unoccupied basis), including all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) the cost of any change to the Work List or Tenant Improvement Work required by Law; (f) the Landlord Supervision Fee (defined in Section 3.2.2 below); (g) sales and use taxes; (h) to the extent necessary, moving and/or temporarily storing any of Landlord’s Furniture (as defined in Exhibit F hereto) during performance of the Tenant Improvement Work; and (i) all other costs expended by Landlord in connection with the performance of the Tenant Improvement Work.
|
2
|
WORK LIST AND PRICING.
|
2.1 Work List. Landlord shall perform Tenant Improvement Work in accordance with the following work list (the “Work List”) using Building-standard methods, materials and finishes.
WORK LIST
|
ITEM
|
|
|
1.
|
Remove demising wall between Suites 210 and 230; patch wall scars as necessary; provide for flooring transition.
|
|
2.
|
Remove current entry door and frame to the Premises.
|
|
3.
|
Install double door entry to the Premises including wall cut-in, new frame, new doors, new lockset
|
|
4.
|
Remove wall and door in current “Marina” conference room located in the interior of the Premises.
|
|
5.
|
Remove partial wall in server room located in the interior of the Premises; install seven (7) ton cooling unit; provide 300A power supply; provide 150A reserve power supply.
|
|
6.
|
Install one (1) server rack in the server room located in the interior of the Premises.
|
|
7.
|
New paint throughout interior of the Premises.
|
|
8.
|
Create caged area in Building storage area on the floor.
|
|
9.
|
Steam clean carpets in the interior of the Premises.
|
|
10.
|
Remove westerly-most entry door to Suite 230 and fill in with framing, drywall, taping, sanding and paint.
|
|
11.
|
Purchase and install one (1) 20kW uninterrupted power source (UPS) in the interior of the Premises, as more particularly described in Section 8 of Exhibit F hereto.
|
2.2 Responsibility for Approving Work List. Tenant shall be responsible for ensuring that all elements of the design of the Tenant Improvement Work are suitable for Tenant’s use of the Premises, and neither the preparation nor the approval of the Work List by Landlord shall relieve Tenant from such responsibility.
2.3 [Intentionally Omitted.]
2.4 [Intentionally Omitted.]
2.5 [Intentionally Omitted.]
2.6 Construction Pricing. Within 10 business days after the mutual execution and delivery of this Agreement, Landlord shall provide Tenant with Landlord’s reasonable estimate (the “Construction Pricing Proposal”) of the cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Work List. Tenant shall provide Landlord with notice approving or disapproving the Construction Pricing Proposal. If Tenant disapproves the Construction Pricing Proposal, Tenant’s notice of disapproval shall be accompanied by proposed revisions to the Work List that Tenant requests in order to resolve its objections to the Construction Pricing Proposal, and Landlord shall respond as required under Section 2.7 below. Such procedure shall be repeated as necessary until the Construction Pricing Proposal is approved by Tenant. Upon Tenant’s approval of the Construction Pricing Proposal, Landlord may purchase the items set forth in the Construction Pricing Proposal and commence construction relating to such items.
2.7 Revisions to Work List. The Work List shall not be revised without Landlord’s agreement, which agreement may be withheld or conditioned in Landlord’s sole and absolute discretion. If Tenant requests any revision to the Work List, Landlord shall provide Tenant with notice approving or disapproving such revision, and, if Landlord approves such revision, Landlord shall have such revision made and delivered to Tenant, together with notice of any resulting change in the most recent Construction Pricing Proposal, if any, within 10 business days after the later of Landlord’s receipt of such request or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such execution and delivery) if such revision is material, whereupon Tenant, within one (1) business day, shall notify Landlord whether it desires to proceed with such revision. If Landlord has commenced performance of the Tenant Improvement Work, then, in the absence of such authorization, Landlord shall have the option to continue such performance disregarding such revision. Landlord shall not revise the Work List without Tenant’s consent, which shall not be unreasonably withheld, conditioned or delayed.
2.8 Time Deadlines. Tenant shall use its best efforts to cooperate with Landlord and its contractors and other consultants to provide any necessary approvals relating to the Work List, approve the Construction Pricing Proposal and obtain any necessary permits for the Tenant Improvement Work as soon as possible after the execution of this Agreement, and Tenant shall meet with Landlord, in accordance with a schedule determined by Landlord, to discuss the parties’ progress. Without limiting the foregoing, Tenant shall approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline (defined below). As used in this Work Letter, “Tenant’s Approval Deadline” means April 30, 2012; provided, however, that Tenant’s Approval Deadline shall be extended by one day for each day, if any, by which Tenant’s approval of the Construction Pricing Proposal pursuant to Section 2.6 above is delayed by any failure of Landlord to perform its obligations under this Section 2.
|
3
|
CONSTRUCTION.
|
3.1 Contractor. A contractor designated by Landlord (the “Contractor”) shall perform the Tenant Improvement Work. In addition, Landlord may select and/or approve of any subcontractors, mechanics and materialmen used in connection with the performance of the Tenant Improvement Work.
3.2 Construction.
3.2.1 Over-Allowance Amount. If the Construction Pricing Proposal exceeds the Allowance, then, concurrently with its delivery to Landlord of approval of the Construction Pricing Proposal, Tenant shall deliver to Landlord cash in the amount of such excess (the “Over-Allowance Amount”). Any Over-Allowance Amount shall be disbursed by Landlord before the Allowance and pursuant to the same procedure as the Allowance. If, after the Construction Pricing Proposal is approved by Tenant, any revision is made to the Work List or the Tenant Improvement Work that increases the Construction Pricing Proposal, or if the Construction Pricing Proposal is otherwise increased to reflect the actual cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Work List, then Tenant shall deliver any resulting Over-Allowance Amount (or any resulting increase in the Over-Allowance Amount) to Landlord immediately upon Landlord’s request.
3.2.2 Landlord’s Retention of Contractor. Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Work List. Tenant shall pay a construction supervision and management fee (the “Landlord Supervision Fee”) to Landlord in an amount equal to $2,500.00 for the initial Work List items described in Section 2.1 above; provided, however, that if such initial Work List is revised to include additional items, then the Landlord Supervision Fee shall be increased by an amount equal to 3% of the cost of such additional items (provided further that such increase in the Landlord Supervision Fee shall not exceed $6,395.00).
3.2.3 Contractor’s Warranties. Tenant waives all claims against Landlord relating to any defects in the Tenant Improvements; provided, however, that if, within 30 days after substantial completion of the Tenant Improvement Work, Tenant provides notice to Landlord of any non-latent defect in the Tenant Improvements, or if, within 11 months after substantial completion of the Tenant Improvement Work, Tenant provides notice to Landlord of any latent defect in the Tenant Improvements, then Landlord shall, at its option, either (a) assign to Tenant any right Landlord may have under the Construction Contract (defined below) to require the Contractor to correct, or pay for the correction of, such defect, or (b) at Tenant’s expense, use reasonable efforts to enforce such right directly against the Contractor for Tenant’s benefit. As used in this Work Letter, “Construction Contract” means the construction contract between Landlord and the Contractor pursuant to which the Tenant Improvements will be constructed.
|
4
|
COMPLETION.
|
Tenant acknowledges and agrees that the Tenant Improvement Work may be performed during normal business hours before or after the Commencement Date. Landlord and Tenant shall cooperate with each other in order to enable the Tenant Improvement Work to be performed in a timely manner and with as little inconvenience to the operation of Tenant’s business as is reasonably possible. Notwithstanding any contrary provision of this Agreement, any delay in the completion of the Tenant Improvement Work or inconvenience suffered by Tenant during the performance of the Tenant Improvement Work shall not delay the Commencement Date, nor shall it subject Landlord to any liability for any loss or damage resulting therefrom or entitle Tenant to any credit, abatement or adjustment of rent or other sums payable under the Lease.
5. MISCELLANEOUS. Notwithstanding any contrary provision of this Agreement, if Tenant defaults under this Agreement before the Tenant Improvement Work is completed, Landlord’s obligations under this Work Letter shall be excused until such default is cured and Tenant shall be responsible for any resulting delay in the completion of the Tenant Improvement Work. This Work Letter shall not apply to any space other than the Premises.
Exhibit B
EXHIBIT C
PACIFIC SHORES CENTER – BUILDING NUMBER 5
CONFIRMATION LETTER
|
|
_____________________, 20__
|
|
To:
|
_______________________
|
|
|
_______________________
|
|
|
_______________________
|
|
|
_______________________
|
Re: Office Lease (the “Lease”) dated ______________, 20____, between ___________________________, a ________________________ (“Landlord”), and ______________________________, a _____________________ (“Tenant”), concerning Suite _____ on the _______ floor of the building located at 0000 Xxxxxxx Xxxxxxxxx, Xxxxxxx Xxxx, XX 00000, commonly known as Pacific Shores Center – Building Number 5
Lease ID: _____________________________
Business Unit Number: __________________
Dear _________________:
In accordance with the Lease, Tenant accepts possession of the Premises and confirms the following:
|
|
1.
|
The Commencement Date is _____________ and the Expiration Date is _______________.
|
|
|
2.
|
The exact number of rentable square feet within the Premises is _________ square feet, subject to Section 2.1.1 of the Lease.
|
|
|
3.
|
Tenant’s Share, based upon the exact number of rentable square feet within the Premises, is ____________%, subject to Section 2.1.1 of the Lease.
|
Please acknowledge the foregoing by signing all three (3) counterparts of this letter in the space provided below and returning two (2) fully executed counterparts to my attention. Please note that, pursuant to Section 2.1.1 of the Lease, if Tenant fails to execute and return (or, by notice to Landlord, reasonably object to) this letter within five (5) days after receiving it, Tenant shall be deemed to have executed and returned it without exception.
|
“Landlord”:
_______________________________,
a ________________________
By:
Name:
Title:
|
|
|
Agreed and Accepted as of , 20__.
“Tenant”:
_______________________________,
a ________________________
By:
Name:
Title:
|
Exhibit C
PACIFIC SHORES CENTER – BUILDING NUMBER 5
RULES AND REGULATIONS
Tenant shall comply with the following rules and regulations (as modified or supplemented from time to time, the “Rules and Regulations”). Landlord shall not be responsible to Tenant for the nonperformance of any of the Rules and Regulations by any other tenants or occupants of the Project. In the event of any conflict between the Rules and Regulations and the other provisions of this Lease, the latter shall control.
1. Tenant shall not alter any lock or install any new or additional locks or bolts on any doors or windows of the Premises without obtaining Landlord’s prior consent. Tenant shall bear the cost of any lock changes or repairs required by Tenant. Two (2) keys will be furnished by Landlord for the Premises, and any additional keys required by Tenant must be obtained from Landlord at a reasonable cost to be established by Landlord. Upon the termination of this Lease, Tenant shall restore to Landlord all keys of stores, offices and toilet rooms furnished to or otherwise procured by Tenant, and if any such keys are lost, Tenant shall pay Landlord the cost of replacing them or of changing the applicable locks if Landlord deems such changes necessary.
2. All doors opening to public corridors shall be kept closed at all times except for normal ingress and egress to the Premises.
3. Landlord may close and keep locked all entrance and exit doors of the Building during such hours as are customary for comparable buildings in the vicinity of the Building. Tenant shall cause its employees, agents, contractors, invitees and licensees who use Building doors during such hours to securely close and lock them after such use. Any person entering or leaving the Building during such hours, or when the Building doors are otherwise locked, may be required to sign the Building register, and access to the Building may be refused unless such person has proper identification or has a previously arranged access pass. Landlord will furnish passes to persons for whom Tenant requests them. Tenant shall be responsible for all persons for whom Tenant requests passes and shall be liable to Landlord for all acts of such persons. Landlord and its agents shall not be liable for damages for any error with regard to the admission or exclusion of any person to or from the Building. In case of invasion, mob, riot, public excitement or other commotion, Landlord may prevent access to the Building or the Project during the continuance thereof by any means it deems appropriate for the safety and protection of life and property.
4. No furniture, freight or equipment shall be brought into the Building without prior notice to Landlord. All moving activity into or out of the Building shall be scheduled with Landlord and done only at such time and in such manner as Landlord designates. Landlord may prescribe the weight, size and position of all safes and other heavy property brought into the Building and also the times and manner of moving the same in and out of the Building. Safes and other heavy objects shall, if considered necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight. Landlord will not be responsible for loss of or damage to any such safe or property. Any damage to the Building, its contents, occupants or invitees resulting from Tenant’s moving or maintaining any such safe or other heavy property shall be the sole responsibility and expense of Tenant (notwithstanding Sections 7 and 10.4 of this Lease).
5. No furniture, packages, supplies, equipment or merchandise will be received in the Building or carried up or down in the elevators, except between such hours, in such specific elevator and by such personnel as shall be designated by Landlord.
6. Employees of Landlord shall not perform any work or do anything outside their regular duties unless under special instructions from Landlord.
7. No sign, advertisement, notice or handbill shall be exhibited, distributed, painted or affixed by Tenant on any part of the Premises or the Building without Landlord’s prior consent. Tenant shall not disturb, solicit, peddle or canvass any occupant of the Project.
8. The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed, and no foreign substance shall be thrown therein. Notwithstanding Sections 7 and 10.4 of this Lease, Tenant shall bear the expense of any breakage, stoppage or damage resulting from any violation of this rule by Tenant or any of its employees, agents, contractors, invitees or licensees.
9. Tenant shall not overload the floor of the Premises, or xxxx, drive nails or screws or drill into the partitions, woodwork or drywall of the Premises, or otherwise deface the Premises, without Landlord’s prior consent. Tenant shall not purchase bottled water, ice, towel, linen, maintenance or other like services from any person not approved by Landlord.
10. Except for vending machines intended for the sole use of Tenant’s employees and invitees, no vending machine or machines other than fractional horsepower office machines shall be installed, maintained or operated in the Premises without Landlord’s prior consent.
11. Tenant shall not, without Landlord’s prior consent, use, store, install, disturb, spill, remove, release or dispose of, within or about the Premises or any other portion of the Project, any asbestos-containing materials, any solid, liquid or gaseous material now or subsequently considered toxic or hazardous under the provisions of 42 U.S.C. Section 9601 et seq. or any other applicable environmental Law, or any inflammable, explosive or dangerous fluid or substance; provided, however, that Tenant may use, store and dispose of such substances in such amounts as are typically found in similar premises used for general office purposes provided that such use, storage and disposal does not damage any part of the Premises, Building or Project and is performed in a safe manner and in accordance with all Laws. Tenant shall comply with all Laws pertaining to and governing the use of such materials by Tenant and shall remain solely liable for the costs of abatement and removal. No burning candle or other open flame shall be ignited or kept by Tenant in or about the Premises, Building or Project.
12. Tenant shall not, without Landlord’s prior consent, use any method of heating or air conditioning other than that supplied by Landlord.
13. Tenant shall not use or keep any foul or noxious gas or substance in or on the Premises, or occupy or use the Premises in a manner offensive or objectionable to Landlord or other occupants of the Project by reason of noise, odors or vibrations, or interfere with other occupants or those having business therein, whether by the use of any musical instrument, radio, CD player or otherwise. Tenant shall not throw anything out of doors, windows or skylights or down passageways.
14. Tenant shall not bring into or keep within the Project, the Building or the Premises any animals (other than service animals), birds, aquariums, or, except in areas designated by Landlord, bicycles or other vehicles.
15. No cooking shall be done in the Premises, nor shall the Premises be used for lodging, for living quarters or sleeping apartments, or for any improper, objectionable or immoral purposes. Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and brewing coffee, tea, hot chocolate and similar beverages for employees and invitees, provided that such use complies with all Laws.
16. The Premises shall not be used for manufacturing or for the storage of merchandise except to the extent such storage may be incidental to the Permitted Use. Tenant shall not occupy the Premises as an office for a messenger-type operation or dispatch office, public stenographer or typist, or for the manufacture or sale of liquor, narcotics or tobacco, or as a medical office, a xxxxxx or manicure shop, or an employment bureau, without Landlord’s prior consent. Tenant shall not engage or pay any employees in the Premises except those actually working for Tenant in the Premises, nor advertise for laborers giving an address at the Premises.
17. Landlord may exclude from the Project any person who, in Landlord’s judgment, is intoxicated or under the influence of liquor or drugs, or who violates any of these Rules and Regulations.
18. Tenant shall not loiter in or on the entrances, corridors, sidewalks, lobbies, courts, halls, stairways, elevators, vestibules or any Common Areas for the purpose of smoking tobacco products or for any other purpose, nor in any way obstruct such areas, and shall use them only as a means of ingress and egress for the Premises.
19. Tenant shall not waste electricity, water or air conditioning, shall cooperate with Landlord to ensure the most effective operation of the Building’s heating and air conditioning system, and shall not attempt to adjust any controls. Tenant shall install and use in the Premises only ENERGY STAR rated equipment, where available. Tenant shall use recycled paper in the Premises to the extent consistent with its business requirements.
20. Tenant shall store all its trash and garbage inside the Premises. No material shall be placed in the trash or garbage receptacles if, under Law, it may not be disposed of in the ordinary and customary manner of disposing of trash and garbage in the vicinity of the Building. All trash, garbage and refuse disposal shall be made only through entryways and elevators provided for such purposes at such times as Landlord shall designate. Tenant shall comply with Landlord’s recycling program, if any.
21. Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any governmental agency.
22. Any persons employed by Tenant to do janitorial work shall be subject to Landlord’s prior consent and, while in the Building and outside of the Premises, shall be subject to the control and direction of the Building manager (but not as an agent or employee of such manager or Landlord), and Tenant shall be responsible for all acts of such persons.
23. No awning or other projection shall be attached to the outside walls of the Building without Landlord’s prior consent. Other than Landlord’s Building-standard window coverings, no curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises. All electrical ceiling fixtures hung in the Premises or spaces along the perimeter of the Building must be fluorescent and/or of a quality, type, design and a warm white bulb color approved in advance by Landlord. Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without Landlord’s prior consent. Tenant shall abide by Landlord’s regulations concerning the opening and closing of window coverings.
24. Tenant shall not obstruct any sashes, sash doors, skylights, windows or doors that reflect or admit light or air into the halls, passageways or other public places in the Building, nor shall Tenant place any bottles, parcels or other articles on the windowsills.
25. Tenant must comply with requests by Landlord concerning the informing of their employees of items of importance to the Landlord.
26. Tenant must comply with the State of California “No-Smoking” law set forth in California Labor Code Section 6404.5 and with any local “No-Smoking” ordinance that is not superseded by such law.
27. Tenant shall cooperate in any reasonable safety or security program developed by Landlord or required by Law.
28. All office equipment of an electrical or mechanical nature shall be placed by Tenant in the Premises in settings approved by Landlord, to absorb or prevent any vibration, noise or annoyance.
29. Tenant shall not use any hand trucks except those equipped with rubber tires and rubber side guards.
30. No auction, liquidation, fire sale, going-out-of-business or bankruptcy sale shall be conducted in the Premises without Landlord’s prior consent.
31. Without Landlord’s prior consent, Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises.
Landlord may from time to time modify or supplement these Rules and Regulations in a manner that, in Landlord’s reasonable judgment, is appropriate for the management, safety, care and cleanliness of the Premises, the Building, the Common Areas and the Project, for the preservation of good order therein, and for the convenience of other occupants and tenants thereof. Landlord may waive any of these Rules and Regulations for the benefit of any tenant, but no such waiver shall be construed as a waiver of such Rule and Regulation in favor of any other tenant nor prevent Landlord from thereafter enforcing such Rule and Regulation against any tenant.
Exhibit D
EXHIBIT E
PACIFIC SHORES CENTER – BUILDING NUMBER 5
JUDICIAL REFERENCE
IF THE JURY-WAIVER PROVISIONS OF SECTION 25.8 OF THIS LEASE ARE NOT ENFORCEABLE UNDER CALIFORNIA LAW, THE PROVISIONS SET FORTH BELOW SHALL APPLY.
It is the desire and intention of the parties to agree upon a mechanism and procedure under which controversies and disputes arising out of this Lease or related to the Premises will be resolved in a prompt and expeditious manner. Accordingly, except with respect to actions for unlawful or forcible detainer or with respect to the prejudgment remedy of attachment, any action, proceeding or counterclaim brought by either party hereto against the other (and/or against its officers, directors, employees, agents or subsidiaries or affiliated entities) on any matters arising out of or in any way connected with this Lease, Tenant’s use or occupancy of the Premises and/or any claim of injury or damage, whether sounding in contract, tort, or otherwise, shall be heard and resolved by a referee under the provisions of the California Code of Civil Procedure, Sections 638 — 645.1, inclusive (as same may be amended, or any successor statute(s) thereto) (the “Referee Sections”). Any fee to initiate the judicial reference proceedings and all fees charged and costs incurred by the referee shall be paid by the party initiating such procedure (except that if a reporter is requested by either party, then a reporter shall be present at all proceedings where requested and the fees of such reporter – except for copies ordered by the other parties – shall be borne by the party requesting the reporter); provided however, that allocation of the costs and fees, including any initiation fee, of such proceeding shall be ultimately determined in accordance with Section 25.6 of this Lease. The venue of the proceedings shall be in the county in which the Premises are located. Within 10 days of receipt by any party of a request to resolve any dispute or controversy pursuant to this Exhibit E, the parties shall agree upon a single referee who shall try all issues, whether of fact or law, and report a finding and judgment on such issues as required by the Referee Sections. If the parties are unable to agree upon a referee within such 10-day period, then any party may thereafter file a lawsuit in the county in which the Premises are located for the purpose of appointment of a referee under the Referee Sections. If the referee is appointed by the court, the referee shall be a neutral and impartial retired judge with substantial experience in the relevant matters to be determined, from Jams/Endispute, Inc., ADR Services, Inc. or a similar mediation/arbitration entity approved by each party in its sole and absolute discretion. The proposed referee may be challenged by any party for any of the grounds listed in the Referee Sections. The referee shall have the power to decide all issues of fact and law and report his or her decision on such issues, and to issue all recognized remedies available at law or in equity for any cause of action that is before the referee, including an award of attorneys’ fees and costs in accordance with this Lease. The referee shall not, however, have the power to award punitive damages, nor any other damages that are not permitted by the express provisions of this Lease, and the parties waive any right to recover any such damages. The parties may conduct all discovery as provided in the California Code of Civil Procedure, and the referee shall oversee discovery and may enforce all discovery orders in the same manner as any trial court judge, with rights to regulate discovery and to issue and enforce subpoenas, protective orders and other limitations on discovery available under California Law. The reference proceeding shall be conducted in accordance with California Law (including the rules of evidence), and in all regards, the referee shall follow California Law applicable at the time of the reference proceeding. The parties shall promptly and diligently cooperate with one another and the referee, and shall perform such acts as may be necessary to obtain a prompt and expeditious resolution of the dispute or controversy in accordance with the terms of this Exhibit E. In this regard, the parties agree that the parties and the referee shall use best efforts to ensure that (a) discovery be conducted for a period no longer than six (6) months from the date the referee is appointed, excluding motions regarding discovery, and (b) a trial date be set within 9 months of the date the referee is appointed. In accordance with Section 644 of the California Code of Civil Procedure, the decision of the referee upon the whole issue must stand as the decision of the court, and upon the filing of the statement of decision with the clerk of the court, or with the judge if there is no clerk, judgment may be entered thereon in the same manner as if the action had been tried by the court. Any decision of the referee and/or judgment or other order entered thereon shall be appealable to the same extent and in the same manner that such decision, judgment, or order would be appealable if rendered by a judge of the superior court in which venue is proper hereunder. The referee shall in his/her statement of decision set forth his/her findings of fact and conclusions of law. The parties intend this general reference agreement to be specifically enforceable in accordance with the Code of Civil Procedure. Nothing in this Exhibit E shall prejudice the right of any party to obtain provisional relief or other equitable remedies from a court of competent jurisdiction as shall otherwise be available under the Code of Civil Procedure and/or applicable court rules.
Exhibit E
EXHIBIT F
PACIFIC SHORES CENTER – BUILDING NUMBER 5
ADDITIONAL PROVISIONS
|
1.
|
ENVIRONMENTAL DISCLOSURE. Pursuant to Section 25359.7 of the California Health and Safety Code, Landlord hereby discloses to Tenant the condition of the Property described in that certain Phase I Environmental Site Assessment dated February, 2012, prepared by Enviro-Sciences (of Delaware), Inc. Tenant acknowledges that Landlord has made a copy of such report available to Tenant (without warranty as to its accuracy or completeness), and the Tenant has fully reviewed such report.
|
|
2.
|
ACKNOWLEDGEMENT OF NOTICES. Landlord has provided and Tenant hereby acknowledges receipt of the notices attached as Exhibit G and Exhibit H hereto, concerning the presence of certain uses and operations of neighboring parcels of land.
|
|
3.
|
EXCESS ALLOWANCE. Notwithstanding any contrary provision of this Lease, if any portion of the Allowance remains after the Allowance Items have been fully paid for, Landlord, upon Tenant’s request, shall disburse such portion of the Allowance (the “Excess Allowance”) to Tenant, to be applied toward the reasonable costs of purchasing Tenant’s furniture, equipment and/or other personal property for the Premises (not to exceed $2.00 per rentable square foot of the Premises), within 30 days after receiving paid invoices from Tenant with respect to such costs. Notwithstanding the foregoing, if Tenant fails to use the entire Excess Allowance within one (1) year following the Commencement Date, the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto.
|
|
4.
|
EARLY ENTRY. Tenant may enter the Premises 14 days before the Commencement Date solely for the purpose of installing telecommunications and data cabling, equipment, furnishings and other personal property in the Premises. Other than the obligation to pay Monthly Rent, all of Tenant’s obligations hereunder shall apply during any period of such early entry. Notwithstanding the foregoing, Landlord may limit, suspend or terminate Tenant’s rights to enter the Premises pursuant to this Section 4 if Landlord reasonably determines that such entry is endangering individuals working in the Premises or is delaying completion of the Tenant Improvement Work. Notwithstanding any contrary provision hereof, the Commencement Date shall be postponed to the extent necessary to allow Tenant 14 days’ entry into the Premises before the Commencement Date pursuant to this Section 4 for the purpose of installing telecommunications, data cabling, equipment, furnishings and other personal property in the Premises.
|
|
5.
|
MONUMENT SIGNAGE.
|
|
|
5.1.
|
Tenant’s Right to Monument Signage. Subject to the terms of this Section 5, from and after the Commencement Date, Tenant shall have the right to have signage (“Tenant’s Monument Signage”) bearing Tenant’s Name (defined below) installed on a panel, selected by Landlord, of the monument sign located at the northwesterly-most drive aisle to the Building (the “Monument Sign”). As used herein, “Tenant Name” means, at any time, at Tenant’s discretion, (i) the name of Tenant set forth in the first paragraph of this Lease (“Tenant’s Existing Name”), or (ii) if Tenant’s name is not then Tenant’s Existing Name, then Tenant’s name, provided that such name is compatible with a first-class office building, as determined by Landlord in its reasonable discretion, and/or (iii) Tenant’s logo, provided that such logo is then being used by Tenant on a substantially nationwide basis and is compatible with a first-class office building, as determined by Landlord in its reasonable discretion. Notwithstanding any contrary provision hereof, (i) Tenant’s rights under this Section 5 shall be personal to the party named as Tenant in the first paragraph of this Lease (“Original Tenant”) and to any successor to Original Tenant’s interest in the Lease that acquires its interest in the Lease solely by means of one or more Permitted Transfers originating with Original Tenant, and may not be transferred to any other party; and (ii) if at any time a Signage Default (defined below) occurs or the Minimum Occupancy Requirement (defined below) is not satisfied, then, at Landlord’s option (which shall not be deemed waived by the passage of time), Tenant shall no longer have any further rights under this Section 5, even if such Signage Default is later cured and/or the Minimum Occupancy Requirement later becomes satisfied, as applicable. For purposes hereof, a “Signage Default” shall be deemed to occur if and only if (x) after a Default occurs, Landlord provides Tenant with notice that Tenant may lose its right to Tenant’s Monument Signage under this Section 5 if Tenant fails to cure such Default within five (5) business days after such notice, and (y) such Default is not cured within such 5-business-day period. For purposes hereof, the “Minimum Occupancy Requirement” shall be deemed satisfied if and only if a portion of the Premises containing at least 8,000 rentable square feet has not been subleased, in whole or in part, for more than 75% of the balance of the term of the Lease.
|
|
|
5.2.
|
Landlord’s Approval. Any proposed Tenant’s Monument Signage shall comply with all applicable Laws and shall be subject to Landlord’s prior written consent. Without limitation, Landlord may withhold consent to any Tenant’s Monument Signage that, in Landlord’s sole judgment, is not harmonious with the design standards of the Building and Monument Sign, and Landlord may require that Tenant’s Monument Signage be of the same size and style as the other signage on the Monument Sign. To obtain Landlord’s consent, Tenant shall submit design drawings to Landlord showing the type and sizes of all lettering; the colors, finishes and types of materials used in Tenant’s Monument Signage; and (if applicable and Landlord consents thereto) any arrangements for illumination.
|
|
|
5.3.
|
Fabrication; Installation; Maintenance; Removal; Costs. Landlord shall (a) fabricate (substantially in accordance with Tenant’s design approved by Landlord), install and, at the expiration or earlier termination of Tenant’s rights under this Section 5, remove Tenant’s Monument Signage; and (b) maintain, repair, and (if applicable) illuminate the Monument Sign. Tenant shall reimburse Landlord, promptly upon demand, for (x) all costs incurred by Landlord in fabricating, installing or removing Tenant’s Monument Signage, and (y) Tenant’s pro rata share (as determined taking into account any other parties using the Monument Sign) of all costs incurred by Landlord in maintaining, repairing and (if applicable) illuminating the Monument Sign.
|
|
6.
|
CONTINGENCY. Notwithstanding any provision herein to the contrary, this Lease is expressly contingent upon Landlord and Ingenuity Systems Inc., a Delaware corporation (“Existing Tenant”) entering into and delivering an amendment to Existing Tenant’s lease to terminate Existing Tenant’s rights to the Suite 230 portion of the Premises (“Amendment”). If the Amendment has not been executed and delivered by Landlord and Existing Tenant (in each parties’ sole and absolute discretion) on or before April 25, 2012, then this Lease shall be null and void and of no force or effect.
|
|
7.
|
LANDLORD’S FURNITURE. During the Term Tenant may use, within the Premises only and subject to such reasonable terms and conditions as Landlord may impose, the furniture owned by Landlord that is existing in the Premises as of the date of this Lease (“Landlord’s Furniture”). Tenant accepts Landlord’s Furniture in its existing condition, with no representations or warranties as to quality, condition, merchantability or fitness for use, any such warranties being specifically excluded. Tenant, at its expense, shall maintain Landlord’s Furniture in as good condition as exists on the date of delivery of possession thereof to Tenant, ordinary wear and tear excepted. Without limiting the foregoing, Tenant shall be responsible for repairing and/or replacing Landlord’s Furniture to the extent it is damaged by any Casualty during the Term, and shall cause Landlord’s Furniture to be covered by Tenant’s property insurance required under Section 10.2.2 of this Lease. In addition, effective as of the date of expiration or earlier termination of this Lease, Landlord, for good and valuable consideration, the receipt and sufficiency whereof are hereby acknowledged, hereby quitclaims and conveys Landlord’s Furniture to Tenant, whereupon Landlord’s Furniture shall be deemed Tenant’s property for all purposes under this Lease (including Section 15 of this Lease). All warranties of title, quality, condition, fitness of use, and merchantability are hereby excluded and Tenant accepts Landlord’s Furniture in its "as is" / ”where is” condition. Within 30 days after the date hereof, Landlord shall provide Tenant with a Notice describing the Landlord’s Furniture.
|
|
8.
|
UNINTERRUPTED POWER SUPPLY SYSTEM. To the extent shown on the Work List in Exhibit B, Landlord shall install one (1) uninterrupted power supply system (a “UPS”). Tenant, at its expense, shall maintain and repair the UPS in good working order and condition. Without limiting the foregoing, Tenant, at its expense, shall procure and maintain in effect throughout the Term a contract (the “UPS Service Contract”) for the maintenance, repair and replacement of the UPS with a contractor reasonably approved by Landlord. Tenant shall follow all reasonable recommendations of such contractor for the maintenance, repair and replacement of the UPS. The UPS Service Contract shall require the contractor, at intervals of not less than three (3) months, to inspect the UPS and provide to Tenant a report of any defective conditions, together with any recommendations for maintenance, repair and/or replacement. Tenant shall provide Landlord with a copy of the UPS Service Contract and each quarterly service report issued thereunder promptly upon mutual execution or receipt thereof. Upon the expiration or earlier termination of this Lease, Tenant, at its expense, shall remove the UPS, and repair any resulting damage, in accordance with Section 8 of this Lease.
|
Exhibit F
EXHIBIT G
PACIFIC SHORES CENTER – BUILDING NUMBER 5
Notice to Tenants and Transferees of
Current or Future Uses of Adjacent Port Property
Notice is hereby given to all lessees, tenants and transferees of land or interests in land located within the project commonly referred to as the “Pacific Shores Center” of the presence or potential future presence of Port (defined below) related industrial activities on the Port Parcel (defined below). All recipients of this notice should be aware of the following facts:
1. The parcel of Port property adjacent to Pacific Shores Center to the northwest (as more particularly shown on the Exhibit G-1 attached hereto, the “Port Parcel”) is now or may be developed for Port related maritime and industrial uses similar to those occupying other properties along the west side of Seaport Boulevard and to the west of Pacific Shores Center.
2. Such Port related maritime and industrial activities are those which are permitted by the general industrial zoning of the City of Redwood City and may include heavy industrial land uses, including uses which involve the receipt, transport, storage or management of hazardous wastes, aggregates, cement, gravel and similar materials, including the outdoor storage and handling of such materials.
3. Pacific Shores Center Limited Partnership, on behalf of itself, its successors and assigns, has recognized, accepted and approved such uses of the Port Parcel subject to the utilization of Best Available Management Practices (defined on Exhibit G-2 hereof) in the development and use of the Port Parcel. Capitalized terms used but not defined in Exhibit G-2 hereof shall have the meaning(s) given to such term(s) in that certain Agreement of Covenants Running With The Land dated March 27, 1998, between the City of Redwood City, a municipal corporation, acting by and through its Board of Port Commissioners (“Port”) and Pacific Shores Center Limited Partnership, a Delaware limited partnership, recorded March 27, 1998 as Instrument No. 98-042844 in the Official Records of San Mateo County.
4. Despite the use of Best Available Management Practices on the Port Parcel by the Port and its lessees and licensees and despite Pacific Shores Center Limited Partnership’s efforts (and the efforts of its successors and assigns) to ensure compatibility between such uses and those in Pacific Shores Center, it is possible that such uses will cause emissions into the air of dust or other particulate matter, or noise or odorous substances which may be offensive to or be perceived as a nuisance by occupants of Pacific Shores Center.
5. Pursuant to covenants made by Pacific Shores Center Limited Partnership on behalf of its successors and assigns, tenants and lessees, the tenants, lessees and transferees of Pacific Shores Center Limited Partnership have approved and accepted such neighboring uses subject to their utilization of Best Available Management Practices.
6. Any actions to enjoin the continuation of such uses or to recover any damages to persons or property related to their operations are subject to a requirement for prior notice found in recorded covenants by Pacific Shores Center Limited Partnership. The following language is excerpted from such covenants:
“In the event that either party hereto believes that the other has failed to perform any covenant made herein in favor of the other, at least ten (10) days prior to the commencement of any action to enforce the covenants hereunder or to recover damages for the breach thereof, that party who believes that a failure to perform has occurred (the ‘Complaining Party’) shall give written notice (the ‘Notice’) to the party alleged not to have performed the covenant (the ‘Non-Complaining Party’) of the specific nature of the alleged failure and of the intent of the Complaining Party to take action to remedy the breach by the Non-Complaining Party. In the event that the nature of the alleged failure to perform is such that the same cannot reasonably be cured within ten (10) days after receipt of the Notice (the ‘Notice Period’), the Non-Complaining Party shall not be deemed to be in violation of its covenants and no action shall be commenced by the Complaining Party if, within the Notice Period, the Non-Complaining Party commences such cure and thereafter diligently and continuously prosecutes the same to completion within a reasonable time. Provided, however, that the Complaining Party shall not be precluded from recovering any actual damages suffered by reason of the alleged failure to perform prior to or after delivery of the Notice, whether or not such failure is thereafter cured.”
Exhibit G
Exhibit G
Exhibit G-1
EXHIBIT G-1
Exhibit G-1
Exhibit G-1
PACIFIC SHORES CENTER – BUILDING NUMBER 5
[Missing Graphic Reference]
Exhibit G-1
Exhibit G-1
Exhibit G-2
EXHIBIT G-2
Exhibit G-2
Exhibit G-2
PACIFIC SHORES CENTER – BUILDING NUMBER 5
[Missing Graphic Reference]
Exhibit G-2
EXHIBIT H
PACIFIC SHORES CENTER – BUILDING NUMBER 5
Notice to Pacific Shores Tenants, Lessees,
Successors, Assigns and Transferees Regarding
Current or Future Uses of Adjacent RMC Xxxxxxxx and Port of redwood city Property
Notice is hereby given to all tenants, lessees, successors, assigns and transferees of land or interest in land located within the project commonly referred to as the “Pacific Shores Center” of the presence or potential future presence of maritime and industrial activities on RMC Xxxxxxxx and Port of Redwood City property west and adjacent to Pacific Shores Center (as more particularly shown on Exhibit G-1 hereto). Recipients of this notice should be aware of the following:
1. The RMC Xxxxxxxx and Port of Redwood City properties are now devoted to, or will be developed for, maritime and industrial uses.
2. These maritime and industrial uses are those which are permitted by the “Heavy Industry” General Plan designation and general industrial zoning of the City of Redwood City. These uses include, by way of example and not limitation, uses involving the receipt, transport, storage, handling, processing or management of aggregates, cement, concrete, asphalt, soil or other landscaping materials, recyclable metals and plastics, recyclable concrete and asphalt, chemicals, petroleum products, hazardous wastes, and similar materials, including indoor storage, mixing and handling of these materials.
3. These uses may cause, on either a regular or intermittent basis, air emissions, including, without limitation, dust and other particulates, odors, vibrations, loud noises, and heavy truck, rail or marine vessel traffic. These uses may have visual, aesthetic or other aspects that may be offensive or perceived as a nuisance by occupants of Pacific Shores Center.
Exhibit H
