EXHIBIT 10.6
LEASE
BY AND BETWEEN
TRUSTEES OF 4 XXXXXXX ROAD REALTY TRUST
LANDLORD
AND
PREDIX PHARMACEUTICALS HOLDINGS, INC.
TENANT
0 XXXXXXX XXXX
XXXXXXXXX, XXXXXXXXXXXXX
Table of Contents
Page
----
ARTICLE 1 Reference Data.............................................. 1
1.1 Introduction and Subjects Referred To......................... 1
1.2 Exhibits...................................................... 2
ARTICLE 2 Premises and Term........................................... 3
2.1 Premises...................................................... 3
2.2 Term.......................................................... 3
2.3 Extension Option.............................................. 3
2.4 Measurement of the Premises and Building...................... 5
ARTICLE 3 Commencement and Condition.................................. 5
3.1 Commencement Date............................................. 5
3.2 Preparation of the Premises................................... 5
3.3 Conclusiveness of Landlord's Performance...................... 7
3.4 Tenant Delay: Force Majeure................................... 7
3.5 Construction Representatives.................................. 9
3.6 Application of Remaining Contribution......................... 9
3.7 Early Access.................................................. 10
ARTICLE 4 Rent, Additional Rent, Insurance and Other Charges.......... 10
4.1 The Annual Fixed Rent......................................... 10
4.2 Additional Rent............................................... 10
4.2.1 Real Estate Taxes....................................... 11
4.2.2 Operating Costs......................................... 12
4.3 Personal Property and Sales Taxes............................. 16
4.4 Insurance..................................................... 16
4.5 Utilities..................................................... 17
4.6 Late Payment of Rent.......................................... 18
4.7 Security Deposit.............................................. 18
ARTICLE 5 Landlord's Covenants........................................ 20
5.1 Affirmative Covenants......................................... 20
5.1.1 Heat and Air-Conditioning............................... 20
5.1.2 Landscaping............................................. 20
5.1.3 Elevator, Lighting and Electricity...................... 20
5.1.4 Repairs................................................. 21
5.2 Interruption.................................................. 21
5.3 Outside Services.............................................. 21
5.4 Access to Building............................................ 21
5.5 Parking....................................................... 22
5.6 Compliance with Americans with Disabilities Act............... 22
5.7 Hazardous Waste Representation and Covenants.................. 22
5.8 Indemnification............................................... 23
i
Table of Contents
(continued)
Page
----
ARTICLE 6 Tenant's Additional Covenants.................................................. 23
6.1 Affirmative Covenants............................................................ 23
6.1.1 Perform Obligations........................................................ 23
6.1.2 Use........................................................................ 23
6.1.3 Repair and Maintenance..................................................... 23
6.1.4 Compliance with Law........................................................ 24
6.1.5 Indemnification............................................................ 24
6.1.6 Landlord's Right to Enter.................................................. 25
6.1.7 Personal Property at Tenant's Risk......................................... 25
6.1.8 Payment of Landlord's Cost of Enforcement.................................. 25
6.1.9 Yield Up................................................................... 26
6.1.10 Rules and Regulations..................................................... 27
6.1.11 Estoppel Certificate...................................................... 27
6.1.12 Landlord's Expenses For Consents.......................................... 27
6.1.13 Financial Information..................................................... 27
6.2 Negative Covenants............................................................... 27
6.2.1 Assignment and Subletting.................................................. 27
6.2.2 Nuisance................................................................... 31
6.2.3 Floor Load; Heavy Equipment................................................ 31
6.2.4 Electricity................................................................ 32
6.2.5 Installation, Alterations or Additions..................................... 32
6.2.6 Intentionally Deleted...................................................... 33
6.2.7 Signs...................................................................... 33
6.2.8 Oil and Hazardous Materials................................................ 34
ARTICLE 7 Casualty or Taking............................................................. 35
7.1 Termination...................................................................... 35
7.1.1 Termination by Landlord ................................................... 35
7.1.2 Termination by Tenant...................................................... 36
7.2 Restoration...................................................................... 36
7.3 Award............................................................................ 37
7.4 Effect of Casualty or Taking on the Tax Excess and the Operating Cost Excess..... 37
ARTICLE 8 Defaults....................................................................... 37
8.1 Default of Tenant................................................................ 37
8.2 Remedies......................................................................... 38
8.3 Remedies Cumulative.............................................................. 40
8.4 Landlord's Right to Cure Defaults................................................ 40
8.5 Holding Over..................................................................... 41
8.6 Effect of Waivers of Default..................................................... 41
8.7 No Waiver, etc................................................................... 41
8.8 No Accord and Satisfaction....................................................... 41
ii
Table of Contents
(continued)
Page
----
ARTICLE 9 Rights of Holders.............................................................. 42
9.1 Rights of Mortgagees or Ground Lessor............................................ 42
9.2 Modifications.................................................................... 43
9.3 Subordination, Non-Disturbance and Attornment.................................... 43
ARTICLE 10 Miscellaneous Provisions...................................................... 43
10.1 Notices.......................................................................... 43
10.2 Quiet Enjoyment; Landlord's Right to Make Alterations, Etc....................... 43
10.3 Recording of Lease; Confidentiality of Lease Terms............................... 44
10.4 Assignment of Rents and Transfer of Title; Limitation of Landlord's Liability.... 44
10.5 Landlord's Default............................................................... 45
10.6 Notice to Mortgagee and Ground Lessor............................................ 46
10.7 Brokerage........................................................................ 46
10.8 Applicable Law and Construction.................................................. 46
iii
LEASE
0 Xxxxxxx Xxxx
Xxxxxxxxx, Xxxxxxxxxxxxx
ARTICLE 1
Reference Data
1.1 Introduction and Subjects Referred To.
This is a lease (this "Lease") entered into by and between Trustees of 0
Xxxxxxx Xxxx Realty Trust, under Declaration of Trust dated January 30, 1998 and
filed with Middlesex County Registry District of the Land Court as Document No.
1054066 ("Landlord") and Predix Pharmaceuticals Holdings, Inc., a Delaware
corporation ("Tenant").
Each reference in this Lease to any of the following terms or phrases
shall be construed to incorporate the corresponding definition stated in this
Section 1.1.
Date of this Lease: January 25, 2005.
Building and Property: That building in the Town of Lexington,
Massachusetts known as 0 Xxxxxxx Xxxx (the
"Building"). The Building and the land parcels
on which it is located and the sidewalks
adjacent thereto are hereinafter collectively
referred to as the "Property".
Premises: A portion of the first floor of the Building
containing a pH neutralization tank and related
equipment, the exact location and size to be
determined by Landlord and Tenant by the Final
Plans Date, and the entire rentable area on the
second floor of the Building, substantially as
shown on Exhibit A hereto.
Premises Rentable Area: 27,500 square feet, subject to the provisions of
Section 2.4.
Original Term: Seven (7) years and two (2) months, commencing
on the Commencement Date and expiring on the day
preceding the seventh anniversary of the Rent
Commencement Date.
Annual Fixed Rent: The sum of (i) for the period commencing on the
Rent Commencement Date and expiring on the day
preceding the first anniversary of the Rent
Commencement Date, $16.29 per square foot of
Premises Rentable Area, (ii) for the period
commencing on the first anniversary of the Rent
Commencement Date and expiring on the day
preceding the second anniversary of the Rent
Commencement Date, $19.55
-1-
per square foot of Premises Rentable Area, (iii)
for the period commencing on the second
anniversary of the Rent Commencement Date and
expiring on the day preceding the fifth
anniversary of the Rent Commencement Date,
$25.00 per square foot of Premises Rentable Area
per annum, and (iv) for the remaining two (2)
years of the Original Term, $27.50 per square
foot of Premises Rentable Area per annum. The
first Year shall be the period commencing on the
Rent Commencement Date and expiring on the day
preceding the first anniversary of the Rent
Commencement Date, and each subsequent
twelve-month period shall be a subsequent Year.
Tenant's Percentage: Fifty percent (50%), subject to the provisions
of Section 2.4.
Permitted Uses: General offices and pharmaceutical research and
laboratory purposes and any other lawful
purposes ancillary to the aforesaid principle
uses, subject to the provisions of Subsection
6.1.2.
Plan Submission Date: March 2, 2005.
Final Plans Date: March 31, 2005.
Security Deposit: $450,000, subject to reduction as provided in
Section 4.7.
Commercial General $5,000,000 per occurrence (combined single
Liability Insurance limit) for property damage, bodily and personal
Limits: injury and death.
Original Address of c/o Reit Management & Research LLC
Landlord: 000 Xxxxxx Xxxxxx
Xxxxxx, Xxxxxxxxxxxxx 00000
Original Address of 10K Xxxx Street
Tenant: Xxxxxx, Xxxxxxxxxxxxx 00000
1.2 Exhibits.
The Exhibits listed below in this section are incorporated in this Lease
by reference and are to be construed as a part of this Lease.
EXHIBIT A. Plan showing the Premises.
EXHIBIT A-1. Plan Showing Location of Tenant's Visitor Parking Spaces
EXHIBIT B. Rules and Regulations.
EXHIBIT C. Alterations Requirements.
EXHIBIT D. Contractor's Insurance Requirements.
EXHIBIT E. Clerk's Certificate.
EXHIBIT 1. Shell and Core Work.
EXHIBIT 2. Exterior Work.
-2-
ARTICLE 2
Premises and Term
2.1 Premises. Landlord hereby leases to Tenant and Tenant hereby leases
from Landlord, subject to and with the benefit of the terms, covenants,
conditions and provisions of this Lease, the Premises, excluding exterior faces
of exterior walls, the common lobbies, hallways, stairways, stairwells, elevator
shafts and other common areas, and the escalators, elevators, pipes, ducts,
conduits, wires and appurtenant fixtures and other common facilities serving the
common areas, the Premises and the premises of other tenants in the Building.
Tenant shall have, as appurtenant to the Premises, rights to use, in
common with others, subject to reasonable rules of general applicability to
tenants of the Building from time to time made by Landlord of which Tenant is
given notice: (a) the common lobbies, hallways and stairways and loading docks
of the Building, (b) the common escalators, elevators, pipes, ducts, conduits,
wires and appurtenant fixtures and other common facilities serving the Premises,
and (c) common walkways and driveways (if any) necessary for access to the
Building.
2.2 Term. The term of this Lease shall be for a period beginning on the
Commencement Date (as defined in Section 3.1) and continuing for the Original
Term and any extension of the term hereof in accordance with the provision of
this Lease, unless sooner terminated as hereinafter provided. When the dates of
the beginning and end of the Original Term have been determined such dates shall
be evidenced by a document executed by Landlord and Tenant and delivered each to
the other, but the failure of Landlord and Tenant to execute or deliver such
document shall have no effect upon such dates. The Original Term and any
extension of the term hereof in accordance with the provisions of this Lease is
hereinafter referred to as the "term" of this Lease.
2.3 Extension Option. So long as this Lease is still in full force and
effect, and the named Tenant as set forth in Section 1.1(or any successor by
merger, or any Affiliate) shall actually occupy at least seventy percent (70%)
of the Premises, Tenant shall have the right to extend the term of this Lease
for two (2) additional periods (the "Extended Term(s)") of three (3) years each.
Each Extended Term shall commence on the day succeeding the expiration of the
Original Term or the preceding Extended Term, as the case may be, and shall end
on the day immediately preceding the third anniversary of the commencement of
such Extended Term. All of the terms, covenants and provisions of this Lease
applicable immediately prior to the expiration of the then current term (i.e.
Original Term or Extended Term, as applicable) shall apply to each such Extended
Term except that (i) the Annual Fixed Rent for each such Extended Term shall be
ninety-five percent (95%) of the Market Rate (as hereinafter defined) for the
Premises determined as of the commencement of such Extended Term, as designated
by Landlord by notice to Tenant ("Landlord's Notice"), but subject to Tenant's
right to dispute as hereinafter provided; and (ii) Tenant shall have no further
right to extend the term of this Lease beyond the Extended Terms hereinabove
provided. If Tenant shall elect to exercise any of the aforesaid options, it
shall do so by giving Landlord notice ("Tenant's Extension Notice") of its
election not later than one year, nor sooner than eighteen (18) months, prior to
the expiration of the then current term of this Lease (Original Term or Extended
Term, as applicable). If Tenant fails to give any such notice to Landlord, the
term of this Lease shall automatically terminate no
-3-
later than the end of the term then in effect, and Tenant shall have no further
option to extend the term of this Lease, it being agreed that time is of the
essence with respect to the giving of any such notice. If Tenant shall extend
the term hereof pursuant to the provisions of this Section 2.3, such extension
shall be automatically effected without the execution of any additional
documents, but Tenant shall, at Landlord's request, execute an agreement
confirming the Annual Fixed Rent for the applicable Extended Term.
"Market Rate" shall mean the then fair market annual rental rate and terms
for the Premises for the applicable period (determined as set forth below).
Within thirty (30) days after Landlord's receipt of a Tenant's Extension Notice,
Landlord shall provide Landlord's Notice. Within thirty (30) days after Tenant's
receipt of Landlord's Notice, Tenant shall either accept Landlord's
determination of the Market Rate or shall propose its determination of the
Market Rate by providing notice to Landlord. If Tenant disagrees with Landlord's
designation of the Market Rate, the parties shall meet for the purpose of
reaching agreement. If the parties cannot agree upon the Market Rate by the date
that is thirty (30) days following Landlord's receipt of Tenant's proposal, then
the Market Rate shall be submitted to appraisal as follows: Within fifteen (15)
days after the expiration of such thirty (30) day period, Landlord and Tenant
shall designate a mutually acceptable appraiser, or either party then may
request the American Arbitration Association, Boston office (or any successor
organization) to designate an independent appraiser in accordance with its then
prevailing rules.
Any appraisers selected as herein provided shall have at least ten (10)
years experience in the leasing, ownership or management of 1,000,000 or more
square feet of floor area of properties of the same type and quality as the
Building in the Route 128 market area. Each party shall pay one half (1/2) of
the fees and expenses of the appraiser and all other expenses of the appraisal.
The parties shall have the opportunity to present evidence in accordance with
reasonable procedures prescribed by the appraiser. The decision and award of the
appraiser shall be in writing and shall be final and conclusive on all parties,
and counterpart copies thereof shall be delivered to both Landlord and Tenant.
Judgment upon the award of the appraiser may be entered in any court of
competent jurisdiction.
The appraiser shall select the Market Rate determination of either
Landlord or Tenant that the appraiser considers closest to his or her own
determination of the Market Rate of the Premises for the applicable Extended
Term and render a decision and award as to such determination to both Landlord
and Tenant (a) within twenty (20) days after the appointment of the appraiser.
In rendering such decision and award, the appraiser shall assume (i) that the
Premises are available in the then rental market, (ii) that Landlord has had a
reasonable time to locate a tenant, (iii) that neither Landlord nor the
prospective tenant is under a compulsion to rent, (iv) that Landlord and Tenant
are typically motivated, well-informed and well-advised, and each is acting in
what it considers its own best interest, (v) the Premises are appropriate and
desired for immediate occupancy by Tenant and contain no work that has been
carried out thereon by Tenant, its subtenant(s), or its or their
successors-in-interest during the Term of this Lease which has diminished the
rental value of the Premises, and (vi) that in the event the Premises are
destroyed or damaged by fire or other casualty prior to the commencement of the
applicable Extended Term, they have been fully restored. In rendering such
decision and award, the appraiser shall consider the fair market annual rents
(as the same may change over time and considering any rent abatement or other
offset against stated annual rents) then being charged for
-4-
comparable space in comparable buildings for the period of the applicable
Extended Term in the Route 128 market area, but shall not modify the provisions
of this Lease.
If the dispute between the parties as to the Market Rate has not been
resolved before the commencement of Tenant's obligation to pay the Annual Fixed
Rent based upon determination of such Market Rate, then Tenant shall pay the
Annual Fixed Rent under the Lease for the annual period just ended until either
the agreement of the parties as to the Market Rate, or the decision of the
appraiser(s), as the case may be, at which time Tenant shall pay any
underpayment of the Annual Fixed Rent to Landlord, or Landlord shall refund any
overpayment of the Annual Fixed Rent to Tenant.
2.4 Measurement of the Premises and Building. Landlord shall cause its
architect to determine the measurement of the Premises and the Building in
accordance with the ANSI/BOMA Z65.1 1996 standards. Such measurement shall occur
only once, shall be made only after reasonable prior notice to Tenant, and at
Tenant's request the architect shall meet with Tenant or its architect to
provide any appropriate substantiation.
If the rentable area of the Premises, as so measured, is different from
the Premises Rentable Area as set forth in Section 1. 1, the definition of
Premises Rentable Area for all purposes (e.g. Annual Fixed Rent, Landlord's
Contribution and the Applied Rent Amount) shall be deemed amended in accordance
with such measurement, and if the Premises Rentable Area as so measured is not
one-half of the rentable area of the Building as so measured ("Building Rentable
Area"), Tenant's Percentage shall be amended to be the ratio of the Premises
Rentable Areas as so measured to Building Rentable Area, all retroactively to
the Commencement Date.
In the event of any adjustment pursuant to this Section 2.3, Landlord and
Tenant shall promptly execute a written statement setting forth the recomputed
Premises Rentable Area and Tenant's Percentage, but the failure by either party
to execute such a statement shall have no effect on the validity of such
recomputation.
ARTICLE 3
Commencement and Condition
3.1 Commencement Date. The Commencement Date shall be the Substantial
Completion Date, as defined in Section 3.2(c).
3.2 Preparation of the Premises.
(a) Landlord and Tenant shall adhere to any schedules for submittals
and decisions reasonably established by The Richmond Group to have final
construction drawings ("Tenant's Plans") for the initial improvements to the
Premises completed on or before the Final Plans Date.
(b) Landlord shall fill in the atrium on the second floor and
perform the alterations and improvements described on Exhibit 1 (the "Shell and
Core Work") and shall perform the alterations and improvements to the exterior
of the Building described on Exhibit 2 (the "Exterior Work"). Landlord shall
cause the improvements to the second floor lobby common
-5-
area to be consistent with adjacent areas of the Premises, and shall seek input
from Tenant regarding the Exterior Work prior to Landlord finalizing plans
therefor.
Promptly after approval by Landlord of Tenant's Plans, Landlord shall also
perform the work specified therein (the "Leasehold Improvement Work", and
together with the Shell and Core Work and the Exterior Work, as may be modified
as hereinafter provided, "Landlord's Work"); and Landlord shall use all
reasonable efforts to complete Landlord's Work diligently, but Tenant shall have
no claim against Landlord or right to terminate this Lease due to failure by
Landlord to complete Landlord's Work by any given date, except as provided in
Section 3.4(d). Landlord shall enter into a contract to perform the Leasehold
Improvement Work with The Richmond Group provided that The Richmond Group shall
execute Landlord's standard form of construction contract containing the
contractor's agreement to perform the Leasehold Improvement Work in accordance
with Tenant's Plans and Landlord's reasonable requirements, including, without
limitation, providing customary contractor insurance and performance and payment
bonds and to substantially complete the Leasehold Improvement Work not later
than August 31, 2005 (the "Target Delivery Date"), subject to Force Majeure and
Tenant Delay, as hereinafter defined; otherwise Landlord shall be free to select
the contractor to perform the Leasehold Improvement Work on the foregoing terms.
Landlord shall perform the Shell and Core Work and the Exterior Work at
its sole cost and expense, in a good and workmanlike manner, using materials
that are new, commercial grade and of first-class quality. Tenant agrees that
Landlord may make any changes in Landlord's Work from that shown on Tenant's
Plans or the Exhibits to this Lease, the necessity or desirability of which
becomes apparent following the Date of this Lease, upon prior written notice to
Tenant for changes that are not substantial (either individually or in the
aggregate) and do not increase the cost of Landlord's Work (either individually
or in the aggregate) and with the approval of Tenant (which approval shall not
be unreasonably withheld or delayed) for all other changes. Landlord shall
provide Tenant with an allowance ("Landlord's Contribution") of One hundred
dollars ($100.00) per square foot of Premises Rentable Area for the performance
of the Leasehold Improvement Work. To the extent that the cost of the Leasehold
Improvement Work exceeds Landlord's Contribution (such excess being the "Excess
Cost"), Tenant shall (at Landlord's election) (i) pay fifty percent (50%) of the
Excess Cost (as estimated by Landlord) to Landlord upon approval by Landlord of
Tenant's Plans and the remainder of such Excess Cost within ten (10) days after
delivery to Tenant of a final accounting of the cost of the Leasehold
Improvement Work, or (ii) pay the entire Excess Cost within ten (10) days after
delivery to Tenant of a final accounting of the cost of Leasehold Improvement
Work. For purposes of this subsection (b), "cost" shall be the actual cost to
Landlord of performing the Leasehold Improvement Work including, without
limitation, all architectural and engineering fees and expenses in preparing
Tenant's Plans or otherwise and all filing fees and other permitting costs and
all contractor charges ("Contractor Charges") for the cost of work and
materials, profit, general conditions and overhead and supervision, plus five
percent (5%) of Contractor Charges as a fee for administering the Leasehold
Improvement Work on behalf of Landlord. Tenant shall, if requested by Landlord,
execute an agreement (the "Excess Cost Amendment") confirming Landlord's
estimate of such Excess Cost, and (subject to Landlord's obligation to
substantiate the actual Excess Cost following completion of Landlord's Work)
Tenant's obligation on account thereof within five (5) Business Days after
Landlord's request therefor.
-6-
(c) The "Substantial Completion Date" shall be the first day as of
which Landlord's Work has been completed except for items of work (and, if
applicable, adjustment of equipment and fixtures) which can be completed after
occupancy has been taken without causing undue interference with Tenant's use of
the Premises (i.e. so-called "punch list" items), and a temporary or permanent
certificate of occupancy has been issued. Landlord shall complete as soon as
conditions permit all "punch list" items and Tenant shall afford Landlord access
to the Premises for such purposes.
3.3 Conclusiveness of Landlord's Performance. Tenant shall be conclusively
deemed to have accepted Landlord's Work unless, within ten (10) months after the
Commencement Date with regard to heat, ventilation and air-conditioning
equipment and related work or within ninety (90) days after the Commencement
Date with regard to other items, Tenant gives Landlord a notice setting forth in
detail those portions of Landlord's Work Tenant does not accept. Upon Tenant's
request, Landlord shall assign to Tenant any warranties provided to Landlord in
connection with Landlord's Work which are assignable without expense to Landlord
provided Tenant shall release Landlord from any liability with respect to the
matter subject to the warranty.
3.4 Tenant Delay; Force Majeure. A "Tenant Delay" shall be any delay in
the occurrence of the Substantial Completion Date as a result of a Direct Delay
(as defined in Section 3.4 (a)), plus any delay in the occurrence of the
Substantial Completion Date as a result of an Additional Delay (as defined in
Section 3.4(b)). Tenant shall pay to Landlord (as Additional Rent), for each day
of Tenant Delay, the amount of Annual Fixed Rent, Additional Rent and other
charges that would have been payable hereunder as if the Rent Commencement Date
occurred, and the obligation to pay the full amount of Annual Fixed Rent,
Additional Rent and other charges (without abatement) had commenced, immediately
prior to such Tenant Delay.
(a) A "Direct Delay" shall be any of the following:
(i) any request by Tenant that Landlord delay in the
commencement or completion of the Leasehold Improvement
Work or any other portions of Landlord's Work for any
reason (other than as a result of Landlord's failure to
perform its obligations under this Lease);
(ii) Tenant's failure to submit Tenant's Plans by the Plan
Submission Date, or to obtain Landlord's approval
thereof by the Final Plans Date, or to execute the
Excess Cost Agreement if requested by Landlord or to pay
when due any Excess Cost;
(iii) any request by Tenant for any change in any of Tenant's
Plans after the Final Plans Date;
(iv) any requirement of Tenant's Plans identified by Landlord
at time of Landlord's approval of Tenant's Plans as a
long lead item; or
(v) any other act or omission of Tenant or its officers,
agents, servants or contractors (including unreasonable
delay or withholding of
-7-
approval to changes desired by Landlord and which
require Tenant's approval, as described in Subsection
3.2(b)).
(b) An "Additional Delay" shall be (i) any reasonably necessary
change in Landlord's construction schedule resulting from a Direct Delay or (ii)
any "Force Majeure" condition (as defined in subsection (e) hereof) which would
have occurred after the Substantial Completion Date but for a Direct Delay.
(c) If, as a result of a Tenant Delay, the Substantial Completion
Date is delayed in the aggregate for more than ninety (90) days, Landlord may
(but shall not be required to) at any time thereafter terminate this Lease by
giving notice of such termination to Tenant and thereupon this Lease shall
terminate without further liability or obligation on the part of either party,
except that Tenant shall pay to Landlord the cost theretofore incurred by
Landlord in performing Landlord's Work, plus an amount equal to Landlord's
out-of-pocket expenses incurred in connection with this Lease, including,
without limitation, brokerage and legal fees, together with any amount required
to be paid pursuant to this Section 3.4 through the date of termination. If as a
result of Force Majeure the Substantial Completion Date is delayed for more than
six (6) months, Landlord may (but shall not be required to) at any time
thereafter terminate this Lease by giving notice of such termination to Tenant
and thereupon this Lease shall terminate without further liability or obligation
on the part of either party.
(d) Landlord shall comply with all of its obligations and enforce
all of its rights under the contract it shall execute for the performance of
Landlord's Work. If nevertheless the Substantial Completion Date has not
occurred within ninety (90) days after the Target Delivery Date (as it may be
extended pursuant to Section 3.4), Tenant shall have the right to terminate this
Lease by giving notice to Landlord not later than thirty (30) days after the
expiration of such ninety (90) day period; and this Lease shall cease and come
to an end without further liability or obligation on the part of either party
(except, if applicable, for any undischarged obligations of Tenant arising
pursuant to Section 3.7, which obligations shall remain in effect) on the giving
of such notice, it being agreed that time is of the essence with respect to the
giving of such notice. Tenant's termination right shall be Tenant's sole and
exclusive remedy at law or in equity for Landlord's failure to complete
Landlord's Work.
(e) "Force Majeure" shall be defined as any strike or other labor
trouble, fire, flood or other casualty, breakage, accident, repairs, unusually
severe weather, governmental preemption of priorities or other controls in
connection with a national or other public emergency, governmental moratoria, or
inaction of governmental authority (or shortages of fuel, supplies or labor
resulting therefrom), war, civil commotion, labor or transportation
difficulties, inability to obtain supplies, or any other cause, whether similar
or dissimilar, beyond Landlord's reasonable control.
(f) The Target Delivery Date shall be extended by the number of days
of delay due to any Tenant Delay or Force Majeure.
-8-
3.5 Construction Representatives. Both Landlord and Tenant shall appoint
one individual as its "Construction Representative" who is authorized to act on
its behalf in connection with any matters arising pursuant to this Article 3.
The Construction Representative may be changed from time to time by notice
hereunder from the then current Construction Representative to the other party's
Construction Representative or by notice from Landlord or Tenant pursuant to
Section 10.1. The initial Construction Representatives shall be Xxxxxxx Xxxx
(Landlord) and Xxxxxxxxx X. Xxxx (Tenant). Notwithstanding Section 10.1, any
notices or other communication under this Article 3 may be made by letter or
other writing sent by U.S. mail, facsimile or email, provided the communication
is made by one party's Construction Representative to the other party's
Construction Representative.
3.6 Application of Remaining Contribution. To the extent the cost of the
Leasehold Improvement Work shall be less than Landlord's Contribution, Tenant
may apply such difference (the "Difference") toward the following (the
"Associated Costs"): (i) architectural services incurred by Tenant in preparing
Tenant's Plans (including any amounts incurred prior to the Date of this Lease),
(ii) construction management services incurred by Tenant in connection with the
Leasehold Improvement Work, (iii) costs incurred by Tenant to install in the
Premises any "work" as defined in Section 6.2.5 of this Lease including lab
benches and fixtures, (iv) costs (including reasonable third party relocation
management fees) incurred by Tenant in moving from 00X Xxxx Xxxxxx to the
Premises, (v) costs incurred by Tenant to install telephone, data and electrical
cabling and wiring in the Premises and (vi) up to $100,000 of costs incurred by
Tenant to purchase new office furniture; and to the extent of the remaining
Difference, Landlord shall reimburse Tenant for such expenses within thirty (30)
days of receipt of request therefor together with paid invoices, and provided
that there shall exist no Default of Tenant and such invoices are delivered to
Landlord prior to the first anniversary of the Commencement Date.
To the extent the cost of the Leasehold Improvement Work plus any amounts
paid by Landlord toward the Associated Costs shall be less than Landlord's
Contribution, up to the Applied Rent Amount of such remaining difference may be
applied to the first installment(s) of Annual Fixed Rent due hereunder, provided
Tenant shall elect to make such application by notice to Landlord on or before
the Rent Commencement Date. The "Applied Rent Amount" is $5.00 per square foot
of Premises Rentable Area.
Should there remain any portion of Landlord's Contribution that shall not
have been applied toward the cost of the Leasehold Improvement Work, the
Associated Costs or application against Annual Fixed Rent as provided in the
previous paragraph, such remaining portion shall be available to reimburse
Tenant for any "work" as defined in Section 6.2.5 of this Lease performed to the
Premises in compliance with the terms of this Lease, further provided that there
shall exist no Default of Tenant and provided paid invoices for such work are
provided to Landlord on or before the fourth anniversary of the Commencement
Date.
Any portion of Landlord's Contribution not applied toward the cost of the
Leasehold Improvement Work, the Associated Costs, credit against Annual Fixed
Rent or work, as described in the three preceding paragraphs, shall be forfeited
by Tenant and shall become Landlord's property.
-9-
3.7 Early Access. Landlord acknowledges that Tenant desires to occupy a
portion of the Premises of approximately five thousand (5,000) rentable square
feet as soon as possible after May 31, 2005, irrespective of the fact that the
Commencement Date may not have occurred. Landlord therefore agrees that, at such
point as, in Landlord's reasonable judgment, Landlord's Work has proceeded to
such point where Tenant may, in compliance with applicable law and building
codes, occupy such portion as desired by Tenant without interfering with the
performance of Landlord's Work, Tenant may occupy such portion of the Premises
for the Permitted Uses. In connection with such access, Tenant agrees to cease
promptly upon notice from Landlord any activity (including mere possession of
such area) which shall interfere with or delay the performance of Landlord's
Work. Such access by Tenant shall be deemed to be subject to all of the
applicable provisions of this Lease, except that the Commencement Date shall not
be deemed to have occurred but Tenant shall pay rent monthly in advance during
such pre-Commencement Date period at a per annum rate of $16.25 per rentable
square foot so occupied. If Tenant fails or refuses to comply with any of the
obligations described or referred to above, then immediately upon notice to
Tenant, Landlord may revoke Tenant's rights of access to the Premises until the
Commencement Date.
ARTICLE 4
Rent, Additional Rent, Insurance and Other Charges
4.1 The Annual Fixed Rent. Commencing on that date (the "Rent Commencement
Date") which is two (2) months following the Commencement Date, Tenant shall pay
Annual Fixed Rent to Landlord, or as otherwise directed by Landlord, without
offset, abatement (except as provided in Article 7), deduction or demand. Annual
Fixed Rent shall be payable in equal monthly installments, in advance, on the
first day of each and every calendar month after the Rent Commencement Date and
during the term of this Lease, at the Original Address of Landlord, or at such
other place as Landlord shall from time to time designate by notice, by check
drawn on a domestic bank.
Annual Fixed Rent for any partial month shall be prorated on a daily
basis, and if Annual Fixed Rent commences on a day other than the first day of a
calendar month, the first payment which Tenant shall make to Landlord shall be
payable on the date Annual Fixed Rent commences and shall be equal to such
pro-rated amount plus the installment of Annual Fixed Rent for the succeeding
calendar month. Annual Fixed Rent for any month during which Annual Fixed Rent
shall increase after the first day of such month shall be the sum of similarly
pro-rated amounts for both the period prior to such change and the period from
and after such change.
4.2 Additional Rent. Tenant covenants and agrees to pay Tenant's
Percentage of Taxes and Operating Costs as provided in Sections 4.2.1 and 4.2.2,
and all other charges and amounts payable by or due from Tenant to Landlord (all
such amounts referred to in this sentence being "Additional Rent").
-10-
4.2.1 Real Estate Taxes. Tenant shall pay to Landlord, as Additional
Rent, Tenant's Percentage of Taxes (as hereinafter defined) assessed against the
Property (or estimated to be due by governmental authority) for any fiscal tax
period (a "Tax Year") during the term of this Lease (Tenant's Percentage of
Taxes being "Tenant's Tax Obligation"). Upon the request of Tenant, Landlord
shall deliver to Tenant copies of all applicable tax bills and the calculation
of Tenant's Tax Obligation. Except as otherwise provided in the immediately
following paragraph, Tenant shall pay Tenant's Tax Obligation to Landlord at
least thirty (30) days prior to the date or dates within any year during the
term hereof that the same, or any fractional share thereof, shall be due and
payable to any governmental authority responsible for collection of same (as
stated in a notice to Tenant given at least thirty (30) days prior to the date
or dates any such payment shall be due, which notice shall set forth the manner
of computation of Tenant's Tax Obligation due from Tenant), except that such
payment shall be made to Landlord not later than thirty (30) days after such
notice to Tenant, if such notice is given subsequent to the date thirty (30)
days prior to the date the same is due and payable as aforesaid.
Tenant shall pay to Landlord, as Additional Rent on the first day of each
calendar month during the term but otherwise in the manner provided for the
payment of Annual Fixed Rent, estimated payments on account of Tenant's Tax
Obligation, such monthly amounts to be sufficient to provide Landlord by the
time Tax payments are due or are to be made by Landlord a sum equal to Tenant's
Tax Obligation, as reasonably estimated by Landlord from time to time on account
of Taxes for the then current Tax Year. If the total of such monthly remittances
for any Tax Year is greater than Tenant's Tax Obligation for such Tax Year,
Landlord shall credit such overpayment against Tenant's subsequent obligations
on account of Taxes (or promptly refund such overpayment if the term of this
Lease has ended and Tenant has no further obligations to Landlord); if the total
of such remittances is less than Tenant's Tax Obligation for such Tax Year,
Tenant shall pay the difference to Landlord within thirty (30) days after being
so notified by Landlord.
If, after Tenant shall have made all payments due to Landlord pursuant to
this subsection 4.2.1, Landlord shall receive a refund of any portion of Taxes
as a result of an abatement of such Taxes by legal proceedings, settlement or
otherwise, Landlord shall credit to Tenant's subsequent obligations on account
of Taxes (or promptly refund such overpayment if the term of this Lease has
ended and Tenant has no further obligations to Landlord) Tenant's Percentage of
that percentage of the refund (after first deducting any reasonable expenses,
including attorneys', consultants' and appraisers' fees, incurred in connection
with obtaining any such refund) which equals the percentage of the applicable
Tax Year included in the term hereof. In addition to Tenant's rights pursuant to
Mass. Gen Xxxx Xxx. c. 59 Section 59, from time to time, Landlord, in its
reasonable discretion, shall make commercially reasonable efforts to challenge
obvious and materially unfair assessments of Taxes by contesting or objecting to
increases in the determination of the fair market value of the Property.
In the event that the Commencement Date shall occur or the term of this
Lease shall expire or be terminated during any Tax Year, or should the Tax Year
or period of assessment of real estate taxes be changed or be more or less than
one (1) year, or should Tenant's Percentage be modified during any Tax Year due
to a change in the rentable area of the Building and/or the
-11-
Premises or otherwise, as the case may be, then the amount of Tenant's Tax
Obligation which may be otherwise payable by Tenant as provided in this
subsection 4.2.1 shall be pro-rated on a daily basis based on a 365 day Tax
Year.
"Taxes" shall mean all taxes, assessments, excises and other charges and
impositions (including penalties and interest only to the extent due to Tenant's
failure to make payments in accordance with this Section 4.2. 1) which are
general or special, ordinary or extraordinary, foreseen or unforeseen, of any
kind or nature which are levied, assessed or imposed at any time during the term
by any governmental authority upon or against or with respect to the Property,
Landlord or the owner or lessee of personal property used by or on behalf of
Landlord in connection with routine maintenance and operation of the Property,
or taxes in lieu thereof, and additional types of taxes to supplement real
estate taxes due to legal limits imposed thereon. If, at any time during the
term of this Lease, any tax or excise on rents or other taxes, however
described, are levied or assessed against Landlord, either wholly or partially
in substitution for, or in addition to, real estate taxes assessed or levied on
the Property, such tax or excise on rents or other taxes shall be included in
Taxes; however, Taxes shall not include franchise, estate, inheritance,
succession, capital levy, income (except to the extent that a tax on income or
revenue is levied solely on rental revenues and not on other types of income and
then only from rental revenue generated by the Property) or excess profits taxes
assessed on Landlord. Taxes also shall include all court costs, attorneys',
consultants' and accountants' fees, and other expenses incurred by Landlord
contesting Taxes through and including all appeals. Taxes shall include any
estimated payment made by Landlord on account of a fiscal tax period for which
the actual and final amount of taxes for such period has not been determined by
the governmental authority as of the date of any such estimated payment.
4.2.2 Operating Costs. Tenant shall pay to Landlord, as Additional
Rent, Tenant's Percentage of Operating Costs (as hereinafter defined) paid or
incurred by Landlord with respect to the Property in any twelve-month period
established by Landlord (an "Operating Year") during the term of this Lease.
Except as otherwise provided in the immediately following paragraph Tenant shall
pay Tenant's Percentage of Operating Costs ("Tenant's Operating Cost
Obligation") to Landlord within twenty (20) days from the date Landlord shall
furnish to Tenant an itemized statement thereof, prepared, allocated and
computed in accordance with then prevailing customs and practices of the real
estate industry, consistently applied. Any year-end statement by Landlord
relating to Operating Costs (other than an invoice for a monthly estimate) shall
be final and binding upon Tenant unless it shall within thirty (30) days after
receipt thereof, contest any item therein by giving notice to Landlord
specifying each item contested and the reasons therefor.
Tenant shall pay to Landlord, as Additional Rent on the first day of each
calendar month during the term but otherwise in the manner provided for the
payment of Annual Fixed Rent, estimated payments on account of Tenant's
Operating Cost Obligation, such monthly amounts to be sufficient to provide to
Landlord, by the end of each Operating Year, a sum equal to the Tenant's
Operating Cost Obligation for such Operating Year, as reasonably estimated by
Landlord from time to time during such Operating Year. If, at the expiration of
each Operating Year in respect of which monthly installments of Operating Cost
Obligation shall have been made as aforesaid, the total of such monthly
remittances is greater than the Tenant's Operating Cost Obligation for such
Operating Year, Landlord shall credit such overpayment against
-12-
Tenant's subsequent obligations on account of Operating Costs (or promptly
refund such overpayment if the term of this Lease has ended and Tenant has no
further obligation to Landlord); if the total of such remittances is less than
the Operating Cost Obligation for such Operating Year, Tenant shall pay the
difference to Landlord within ten (10) days after being so notified by Landlord.
In the event that the Commencement Date shall occur or the term of this
Lease shall expire or be terminated during any Operating Year or Tenant's
Percentage shall be modified during any Operating Year due to a change in the
rentable area of the Building and/or the Premises or otherwise, as the case may
be, then the amount of Tenant's Operating Cost Obligation which may be payable
by Tenant as provided in this subsection 4.2.2 shall be pro-rated on a daily
basis based on a 365 day Operating Year.
"Operating Costs" shall include all costs and expenses reasonably paid or
incurred for the operation, cleaning, management, maintenance, repair, upkeep
and security of the Property, including, without limitation:
(a) all salaries, wages, fringe benefits, payroll taxes and
workmen's compensation insurance premiums related thereto and all other costs
paid or incurred with respect to employment of personnel engaged in operation,
administration, cleaning, maintenance, repair, upkeep and security of the
Property including, without limitation, supervisors, property managers,
accountants, bookkeepers, janitors, carpenters, engineers, mechanics,
electricians and plumbers;
(b) all utilities and other costs related to provision of heat
(including oil, steam and/or gas), electricity, air conditioning, and water
(including sewer charges) and other utilities to the Property (exclusive of
reimbursement to Landlord for any of same received as a result of direct billing
to any tenant of the Building);
(c) all costs, including supplies, material and equipment costs, for
cleaning and janitorial services to the common areas of the Property (including,
without limitation, exterior window cleaning), and interior and exterior
landscaping and pest control;
(d) the cost of replacements for tools and other similar equipment
used in the repair, maintenance, cleaning and protection of the Property,
provided that, in the case of any such equipment used jointly on other property
of Landlord, such costs shall be suitably prorated among the Property and such
other properties;
(e) all costs and premiums for fire, casualty, rental income,
liability and such other insurance as may be maintained reasonably from time to
time by Landlord relating to the Property;
(f) all costs of maintaining, repairing, decorating, operating,
administering, inspecting and protecting the Property (including, without
limitation, lighting, installation, maintenance, repair and alteration of signs,
snow removal on the Property and adjacent walks and ways, paving, patching and
restriping of parking areas and operation, maintenance, replacement and repair
of heating, ventilating and air conditioning equipment, fire protection and
security systems, elevators, roofs, parking areas and any other common Building
equipment,
-13-
systems or facilities), and all costs of structural and other repairs and
replacements (other than repairs for which Landlord has received full
reimbursement from contractors, other tenants of the Building or from others)
necessary to keep the Property in good working order, repair, appearance and
condition;
(g) costs of compliance with any laws, rules, regulations,
ordinances, agreements or standards applicable to the Building or the Property,
which conformance is not the responsibility of any tenant of the Building, and
which Landlord elects or is required to perform, and costs of testing and
monitoring for any Hazardous Materials (as defined in Section 6.2.8) in the
Building or Property, which is not the responsibility of any tenant of the
Building, and which Landlord elects to perform;
(h) all costs incurred in connection with the administration and
supervision of all matters referred to in items (a) through (g) hereof and in
performing Landlord's obligations under Article 5, including Landlord's office
overhead costs provided that, if any such administrative or supervisory
personnel are also employed on other property of Landlord, such cost of
compensation shall be suitably prorated among the Property and such other
properties;
(i) payments under all service contracts relating to matters
referred to in Items (a) through (h) hereof;
(j) a management fee of three percent (3%) of gross rents payable by
tenants of the Property; and
(k) reasonable attorney's fees and disbursements (exclusive of any
such fees and disbursements incurred in tax abatement proceedings or in the
preparation of leases) and auditing and other professional fees and expenses.
If, after twenty-four months after the Commencement Date and during the
term of this Lease, Landlord shall make any capital expenditure, the total cost
of which is not included in Operating Costs for the Operating Year in which it
was made, Landlord may include in Operating Costs for the Operating Year in
which such expenditure was made and in Operating Costs for each succeeding
Operating Year an annual charge-off of such capital expenditure. Annual
charge-offs shall be equal to the level payments of principal and interest
necessary to amortize the original capital expenditure over the useful life of
the improvement, repair, alteration or replacement made with the capital
expenditure using an interest rate reasonably determined by Landlord as being
the interest rate being charged at the time of the original capital expenditure
for long-term mortgages by institutional lenders on like properties; and the
useful life shall be determined reasonably by Landlord in accordance with then
prevailing customs and practices of the real estate industry, consistently
applied.
Notwithstanding any other contrary provision, Operating Costs shall not
include:
(i) the cost of any additions or expansions to the rentable
areas of the Property;
(ii) any leasehold improvements performed to any premises
intended to be occupied by individual tenants;
-14-
(iii) any reserves for future expenditures not yet incurred;
(iv) ground lease rental;
(v) costs incurred by Landlord for repair or restoration to
the extent that Landlord is reimbursed by insurance or
condemnation proceeds or that the same is covered by
warranty;
(vi) attorneys' fees, leasing commissions and other costs and
expenses incurred in connection with negotiations or
disputes with present or prospective tenants or other
occupants of, or persons, firms or entities with respect
to, the Property;
(vii) expenses in connection with services or benefits that
are not offered to Tenant;
(viii) costs incurred by Landlord due to the negligence or
misconduct (including any violation of law) of Landlord
or its agents, contractors, licensees and employees or
the violation by Landlord or any tenants or other
occupants of the terms and conditions of any lease of
space or other agreements including this Lease;
(ix) interest, principal, points and fees on debts or
amortization on any mortgage or mortgages or any other
debt instrument encumbering all or any portion of the
Property;
(x) all items and services for which Tenant or any other
tenant reimburses Landlord or that Landlord provides
exclusively to one or more tenants (other than Tenant)
but not all tenants;
(xi) advertising and promotional expenditures in connection
with leasing the Property;
(xii) electric power and any other utility costs for which any
tenant or occupant directly contracts with the local
public service company;
(xiii) any costs relating to clean-up of hazardous materials,
asbestos and the like;
(xiv) any charges for depreciation of the Building, fixtures
or otherwise; and
(xv) the cost of any electric current or other utility
furnished to any leasable area of the Building.
In addition, if during any portion of any Operating Year for which
Operating Costs are being computed, less than ninety-five percent (95%) of the
rentable area of the Building was leased to tenants or if Landlord is supplying
less than ninety-five percent (95%) of the rentable
-15-
area of the Building with the services and utilities being supplied hereunder,
Landlord may, at its option, reasonably project, on an item-by-item basis, the
Operating Costs that would have been incurred if ninety-five percent (95%) of
the Building were occupied for such Operating Year and such services and
utilities were being supplied to ninety-five percent (95%) of the rentable area
of the Building, and such projected amount shall, for the purposes hereof, be
deemed to be the Operating Costs for such Operating Year.
4.3 Personal Property and Sales Taxes. Tenant shall pay all taxes charged,
assessed or imposed upon the personal property of Tenant and all taxes on the
sales of services or inventory, merchandise and any other goods by Tenant in or
upon the Premises.
4.4 Insurance. Tenant shall, at its expense, take out and maintain,
throughout the tenor of this Lease, the following insurance:
4.4.1 Commercial general liability insurance (on an occurrence basis
and on a 1988 ISO CGL form or its equivalent, including without limitation,
broad form contractual liability, bodily injury, property damage, fire legal
liability, and products and completed operations coverage) under which Tenant is
named as an insured and Landlord and Reit Management and Research LLC (and the
holder of any mortgage on the Premises or Property, as set out in a notice from
time to time) are named (on an ISO Form 20226 or as otherwise acceptable to
Landlord) as additional insureds as their interests may appear, in an amount
which shall, at the beginning of the term, be at least equal to the Commercial
General Liability Insurance Limits, and, which, from time to time during the
term, shall be for such higher limits, if any, as Landlord shall reasonably
determine to be customarily carried in the area in which the Premises are
located at property comparable to the Premises and used for similar purposes;
Worker's compensation insurance with statutory limits covering all of
Tenant's employees working on the Premises; and
So-called "special form" property insurance on a "replacement cost" basis
with an agreed value endorsement covering all furniture, furnishings, fixtures
and equipment and other personal property brought to the Premises by Tenant and
all improvements and betterments to the Premises performed at Tenant's expense.
4.4.2 All such policies shall contain deductibles not in excess of
that reasonably approved by Landlord, shall contain a clause confirming that
such policy and the coverage evidenced thereby shall be primary with respect to
any insurance policies carried by Landlord and shall be obtained from
responsible companies qualified to do business and in good standing in the state
or district in which the Property is located, which companies shall have a
general policy holder's rating of at least A and a financial class of at least
VIII by A.M. Best Company, Inc.. A copy of each paid-up policy evidencing such
insurance (appropriately authenticated by the insurer) or a certificate (on
XXXXX Form 27 or its equivalent) of the insurer, certifying that such policy has
been issued and paid in full, providing the coverage required by this Section
and containing provisions specified herein, shall be delivered to Landlord prior
to the commencement of the term of this Lease and, upon renewals, not less than
three (3) days prior to the expiration of such coverage. Each such policy shall
be non-cancelable and not materially changed with respect to the interest of
Landlord and such mortgagees of the Property (and others
-16-
that are in privity of estate with Landlord of which Landlord provides notice to
Tenant from time to time) without at least thirty (30) days' prior written
notice thereto. Any insurance required of Tenant under this Lease may be
furnished by Tenant under a blanket policy carried by it provided that such
blanket policy shall reference the Premises, and shall guarantee a minimum limit
available for the Premises equal to the insurance amounts required in this
Lease. Landlord may, at any time, and from time to time, inspect and/or copy any
and all insurance policies required to be procured by Tenant hereunder.
4.4.3 Landlord and Tenant shall each endeavor to secure an
appropriate clause in, or an endorsement upon, each property damage insurance
policy obtained by it and covering the Building, the Premises or the personal
property, fixtures and equipment located therein or thereon, pursuant to which
the respective insurance companies waive subrogation and permit the insured,
prior to any loss, to agree with a third party to waive any claim it might have
against said third party. The waiver of subrogation or permission for waiver of
any claim hereinbefore referred to shall extend to the agents of each party and
its employees and, in the case of Tenant, shall also extend to all other persons
and entities occupying or using the Premises by, through or under Tenant. If and
to the extent that such waiver or permission can be obtained only upon payment
of an additional charge then the party benefiting from the waiver or permission
shall pay such charge upon demand, or shall be deemed to have agreed that the
party obtaining the insurance coverage in question shall be free of any further
obligations under the provisions hereof relating to such waiver or permission
from such insurance companies.
Subject to the foregoing provisions of this Subsection 4.4.3, and insofar
as may be permitted by the terms of the insurance policies carried by it, each
party hereby releases the other with respect to any claim which it might
otherwise have against the other party for any loss or damage, excluding any
deductible amounts, to the extent such damage is actually covered or would have
been covered by policies of insurance required by this Lease to be carried by
the respective parties hereunder. In addition, Tenant agrees to exhaust any and
all claims against its insurer(s) prior to commencing an action against Landlord
for any property loss.
4.5 Utilities. Tenant shall pay all charges related to the supply of
electricity and natural gas to the Premises, whether designated as a charge,
tax, assessment, fee or otherwise, all such charges to be paid as the same from
time to time become due. Except as otherwise provided in this Subsection 4.5 or
in Article 5, it is understood and agreed that Tenant shall make its own
arrangements for the installation or provision of all utilities and services and
that Landlord shall be under no obligation to furnish any utilities to the
Premises.
Tenant acknowledges that Annual Fixed Rent does not include the cost of
supplying electricity or water and sewer service to the Premises. If the utility
serving the Premises shall agree to separate metering, electricity usage shall
be separately metered (and the cost of installing such separate metering shall
be included as part of the Shell and Core Work) and Tenant shall pay all bills
for the supply of electricity to the Premises during the term of this Lease
directly to the utility company furnishing the same. If such separate metering
is not available with respect to the Premises, then Tenant shall, during such
portion of the term as such separate metering is not in effect, pay as
Additional Rent all cost of electricity supplied to the Premises as determined
in good faith by Landlord by submetering or similar device and the cost of
operating, maintaining and repairing (but not installing, which shall be done as
part of the
-17-
Shell and Core Work, if applicable) any meter or other device used to measure
Tenant's electrical consumption and any cost incurred by Landlord in keeping
account of or determining Tenant's electrical consumption. Tenant shall pay as
Additional Rent all cost of water and sewer service for the Premises during the
term as determined by Landlord by submetering or other similar device and the
cost of operating, maintaining and repairing (but not installing, which shall be
done as part of the Shell and Core Work) any meter or other device used to
measure water consumption and any cost incurred by Landlord in keeping account
of or determining Tenant's water consumption. Alternatively, at Landlord's
option, Tenant shall pay Tenant's Percentage of the charges for electricity
service and/or the charges for water and sewer service during the term allocable
to those portions of the Building leased or intended to be leased to tenants,
within ten days of invoice therefor, provided however if some or all of the
areas leased or intended to be leased to tenants are separately metered for
electricity and/or water, such Tenant's Percentage for purposes of this
Subsection 4.5 only shall be determined by dividing the rentable area of the
Premises by the rentable area of the portions of the Building not separately
metered for such service.
4.6 Late Payment of Rent. If any installment of Annual Fixed Rent or any
Additional Rent is not paid on or before the date the same is due, it shall bear
interest (as Additional Rent) from the date due until the date paid at the
Default Rate (as defined in Section 8.4). In addition, if any installment of
Annual Fixed Rent or Additional Rent is unpaid for more than ten (10) days after
the date due, Tenant shall pay to Landlord a late charge equal to the greater of
One Hundred Dollars ($100) or three percent (3%) of the delinquent amount. The
parties agree that the amount of such late charge represents a reasonable
estimate of the cost and expense that would be incurred by Landlord in
processing and administration of each delinquent payment by Tenant, but the
payment of such late charges shall not excuse or cure any default by Tenant
under this Lease. Absent specific provision to the contrary, all Additional Rent
shall be due and payable in full ten (10) days after demand by Landlord.
4.7 Security Deposit. Upon execution of this Lease, Tenant shall deposit
with Landlord the Security Deposit. The Security Deposit shall be held by
Landlord as security for the faithful performance of all the terms of this Lease
to be observed and performed by Tenant. The Security Deposit shall not be
mortgaged, assigned, transferred or encumbered by Tenant and any such act on the
part of Tenant shall be without force and effect and shall not be binding upon
Landlord. Tenant shall cause the Security Deposit to be maintained throughout
the term in the amount set forth in Section 1.1, subject to reduction as
hereinafter provided. The Security Deposit shall be reduced to $350,000 as of
the first anniversary of the Rent Commencement Date, to $250,000 as of the
second anniversary of the Rent Commencement Date, to $150,000 as of the third
anniversary of the Rent Commencement Date, and to $100,000 as of the fourth
anniversary of the Rent Commencement Date; provided, however, that no reduction
in the Security Deposit shall occur once there shall have existed a Default of
Tenant as defined in Section 8.1.
Tenant shall have the right to post the Security Deposit in the form of a
letter of credit (the "Letter of Credit"), which shall (a) be unconditional and
irrevocable and otherwise in form and substance reasonably satisfactory to
Landlord; (b) permit multiple draws; (c) be issued by a commercial bank
reasonably acceptable to Landlord from time to time; (d) be made payable to, and
expressly transferable and assignable at no charge by, Landlord but only to the
holder from
-18-
time to time of the interest of Landlord under this Lease (and if the issuer
shall impose a charge for transfer, Tenant shall pay such charge); (e) be
payable at sight upon presentment of a sight draft accompanied by a certificate
of Landlord stating either that Tenant is in default under this Lease or that
Landlord is otherwise permitted to draw upon such Letter of Credit under the
express terms of this Lease, and the amount that Landlord is owed (or is
permitted to draw) in connection therewith; and (f) either expire not earlier
than ninety (90) days following the expiration of the tern of this Lease, or be
replaced not less than thirty (30) days prior to the expiration of the then
current Letter of Credit so that the original Letter of Credit or a replacement
thereof shall be in full force and effect throughout the term of this Lease and
for a period of at least ninety (90) days thereafter. Tenant shall maintain the
Letter of Credit in the amount of the Security Deposit as the same may be
reduced as provided above and shall deliver to Landlord any replacement Letter
of Credit not less than thirty (30) days prior to the expiration of the then
current Letter of Credit. Any reduction in the amount of the Letter of Credit
may be accomplished by Landlord's surrender of the existing Letter of Credit in
return for Landlord's contemporaneous receipt of a new Letter of Credit in the
lower amount. Notwithstanding anything in this Lease to the contrary, any grace
period or cure periods which are otherwise applicable under Section 8.1 hereof,
shall not apply to any of the foregoing, and, specifically, if Tenant fails to
comply with the requirements of subsection (f) above or if Tenant shall fail to
maintain the Letter of Credit in the full amount of the Security Deposit after
any draw thereon by Landlord,. Landlord shall have the immediate right to draw
upon the Letter of Credit in full and hold the proceeds thereof as a cash
security deposit. Each Letter of Credit shall be issued by a commercial bank
that has a credit rating with respect to certificates of deposit, short term
deposits or commercial paper of at least P-2 (or equivalent) by Xxxxx'x Investor
Service, Inc., or at least A-2 (or equivalent) by Standard & Poor's Corporation.
If the issuer's credit rating is reduced below P-2 (or equivalent) by Xxxxx'x
Investor Service, Inc., or at least A-2 (or equivalent) by Standard & Poor's
Corporation, or if the financial condition of the issuer changes in any other
materially adverse way, then Landlord shall have the right to require that
Tenant obtain from a different issuer a substitute Letter of Credit that
complies in all respects with the requirements of this Section, and Tenant's
failure to obtain such substitute Letter of Credit within twenty (20) days after
Landlord's demand therefor (with no other notice, or grace or cure period being
applicable thereto) shall entitle Landlord immediately to draw upon the existing
Letter of Credit in full, without any further notice to Tenant. Landlord may
use, apply or retain the proceeds of the Letter of Credit to the same extent
that Landlord may use, apply or retain any cash security deposit, as set forth
herein. If Landlord draws against the Letter of Credit and uses or applies the
proceeds as Landlord could apply the Security Deposit in accordance with this
Lease, Tenant shall, within ten (10) days after notice from Landlord, provide
Landlord with either an additional Letter of Credit in the amount so drawn or an
amendment to the existing Letter of Credit restoring the amount thereof to the
amount initially provided. Tenant hereby agrees to cooperate promptly, at its
expense with Landlord to execute and deliver to Landlord any modifications,
amendments and replacements of the Letter of Credit, as Landlord may reasonably
request to carry out the terms and conditions hereof.
If the Annual Fixed Rent or Additional Rent payable hereunder shall be
overdue and unpaid or should Landlord make any payment on behalf of the Tenant,
or Tenant shall fail to perform any of the terms of this Lease, then Landlord
may, at its option and without notice or prejudice to any other remedy which
Landlord may have on account thereof, appropriate and apply the entire Security
Deposit or so much thereof as may be necessary to compensate
-19-
Landlord toward the payment of Annual Fixed Rent, Additional Rent or other sums
or loss or damage sustained by Landlord due to such breach by Tenant; and Tenant
shall forthwith upon demand restore the Security Deposit to the amount stated in
Section 1.1. Notwithstanding the foregoing, upon the application by Landlord of
all or any portion of the Security Deposit (with or without notice thereof to
Tenant) to compensate Landlord for a failure by Tenant to pay any Annual Fixed
Rent or Additional Rent when due or to perform any other obligation hereunder,
and until Tenant shall have restored the Security Deposit to the amount required
by Section 1.1, Tenant shall be deemed to be in default in the payment of
Additional Rent for purposes of Section 8.l(a)(I) hereof. So long as Tenant
shall not be in default of its obligations under this Lease, Landlord shall
return the Security Deposit, or so much thereof as shall have not theretofore
been applied in accordance with the terms of this Section 4.7 (and less any
amounts Landlord shall estimate shall be due from Tenant following year-end
reconciliation of Operating Costs and Taxes) to Tenant promptly following the
expiration or earlier termination of the term of this Lease and the surrender of
possession of the Premises by Tenant to Landlord in accordance with the terms of
this Lease. While Landlord holds the Security Deposit, Landlord shall have no
obligation to pay interest on the same and shall have the right to commingle the
same with Landlord's other funds. If Landlord conveys Landlord's interest under
this Lease, the Security Deposit, or any part thereof not previously applied,
shall be turned over by Landlord to Landlord's grantee, and Tenant shall look
solely to such grantee for proper application of the Security Deposit in
accordance with the terms of this Section 4.7 and the return thereof in
accordance herewith. The holder of a mortgage on the Property shall not be
responsible to Tenant for the return or application of the Security Deposit,
whether or not it succeeds to the position of Landlord hereunder, unless such
holder actually receives the Security Deposit.
ARTICLE 5
Landlord's Covenants
5.1 Affirmative Covenants. Landlord shall, during the term of this Lease
provide the following:
5.1.1 Heat and Air-Conditioning. Landlord shall maintain the central
Building heat, ventilation and air-conditioning equipment ("HVAC") to provide
outside air and chilled and heated water to a central area in the Premises.
Tenant shall pay, as Additional Rent, all charges (which charges shall include
costs of utilities and maintenance and repair costs) incurred by Landlord to
supply HVAC to the Premises, and Landlord shall substantiate the basis of such
charges using customary industry practices.
5.1.2 Landscaping. Landlord shall provide cleaning, maintenance and
landscaping to the common areas of the Building and Property (including snow
removal to the extent necessary to maintain reasonable access to the Building
and the parking lot) in accordance with standards generally prevailing
throughout the term hereof in comparable office buildings in the Route 128 area.
5.1.3 Elevator, Lighting and Electricity. Landlord shall furnish
non-exclusive elevator service to the Premises; purchase and install, at
Tenant's expense, all lamps, tubes, bulbs, starters and ballasts for lighting
fixtures in the Premises; provide lighting to public and
-20-
common areas of the Property; and arrange for the supply of electrical power to
the Premises to accommodate a load not exceeding the limitations contained in
Section 6.2.4.
5.1.4 Repairs. Except as otherwise expressly provided herein,
Landlord shall promptly and professionally make such repairs and replacements to
the roof, exterior walls, floor slabs and other structural components of the
Building, and to the common areas and facilities of the Building (including any
common area plumbing, electrical and HVAC equipment, elevators and any other
common equipment or systems in the Building) as may be necessary to keep them in
good repair and condition (exclusive of equipment installed by Tenant and except
for those repairs required to be made by Tenant pursuant to Subsection 6.1.3
hereof and repairs or replacements occasioned by any act or negligence of
Tenant, its servants, agents, customers, contractors, employees, invitees, or
licensees).
5.2 Interruption. Landlord shall have no responsibility or liability to
Tenant for failure, interruption, inadequacy, defect or unavailability of any
services, facilities, utilities, repairs or replacements or for any failure or
inability to provide access or to perform any other obligation under this Lease
caused by breakage, accident, fire, flood or other casualty, strikes or other
labor trouble, order or regulation of or by any governmental authority,
inclement weather, repairs, inability to obtain or shortages of utilities,
supplies, labor or materials, war, civil commotion or other emergency,
transportation difficulties or due to any act or neglect of Tenant or Tenant's
servants, agents, employees or licensees or for any other cause beyond the
reasonable control of Landlord, and in no event shall Landlord be liable to
Tenant for any indirect or consequential damages suffered by Tenant due to any
such failure, interruption, inadequacy, defect or unavailability; and failure or
omission on the part of Landlord to furnish any of same for any of the reasons
set forth in this paragraph shall not be construed as an eviction of Tenant,
actual or constructive, nor entitle Tenant to an abatement of rent, nor render
the Landlord liable in damages, nor release Tenant from prompt fulfillment of
any of its covenants under this Lease.
Landlord reserves the right to deny access to the Building and to
interrupt the services of the HVAC, plumbing, electrical or other mechanical
systems or facilities in the Building when necessary from time to time by reason
of accident or emergency, or for repairs, alterations, replacements or
improvements which in the reasonable judgment of Landlord are desirable or
necessary, until such repairs, alterations, replacements or improvements shall
have been completed. Landlord shall use reasonable efforts to minimize the
duration of any such interruption and to give to Tenant at least three (3) days'
notice if service is to be interrupted, except in cases of emergency.
5.3 Outside Services. In the event Tenant wishes to obtain services or to
hire vendors relating to the Premises, Tenant shall first obtain the prior
approval of Landlord for the installation and/or utilization of such services or
vendors. Landlord's approval may not be withheld, conditioned or delayed
unreasonably. Such services shall include, but shall not be limited to, utility
providers, security services, moving services, equipment servicers and
installers, catering services and the like. Notwithstanding any Landlord
approval of the installation and/or utilization of such services or vendors,
such installation and utilization shall be at Tenant's sole cost, risk and
expense.
5.4 Access to Building. During Normal Building Operating Hours, the
Building
-21-
shall, subject to the provisions of Section 5.2, be open and access to the
Premises shall be freely available, subject to the Rules and Regulations. During
periods other than Normal Building Operating Hours, Tenant shall have access to
the Premises, but such access shall also be subject to the Rules and
Regulations. Tenant acknowledges that Tenant is responsible for providing
(subject to the terms of this Lease) such security to and for its property and
personnel in the Premises as it deems appropriate.
5.5 Parking. During the term of this Lease, Landlord shall provide Tenant
with access to parking spaces on the Property as follows:
(a) Tenant shall be entitled to 3.6 parking spaces per 1,000 square
feet of Premises Rentable Area, rounded down to the nearest whole number. All
such parking spaces shall be unreserved and available on a first-come,
first-served basis, except that six (6) spaces, in the location shown on Exhibit
A-1, shall be identified as reserved for Tenant's visitors.
(b) Tenant shall use such parking spaces solely for the parking of
passenger vehicles of Tenant and Tenant's employees, business invitees and
guests only.
(c) Landlord reserves the right to implement and modify systems to
regulate access to and use of the parking spaces, including, without limitation,
parking passes, parking stickers and card key access, or any other system
reasonably designated by Landlord.
(d) Tenant hereby indemnifies and shall defend and hold Landlord
harmless form and against all claims, loss, cost or damage arising out of the
use by Tenant and Tenant's employees and invitees of the parking spaces, except
to the extent caused by the willful misconduct or gross negligence of Landlord
or Landlord's agent or employees.
5.6 Compliance with Americans with Disabilities Act. As of the
Commencement Date, the common areas of the Property shall, to Landlord's
knowledge, be in material compliance with the Americans with Disabilities Act of
1990, as amended and all other applicable laws and regulations concerning access
to and use of facilities like the Building by people with disabilities,
including without limitation, the Massachusetts Architectural Business Board
regulations (collectively, the "ADA"). If during the term of this Lease any
improvement or alteration to the common areas of the Property is necessary for
compliance with the ADA and the obligation to make such improvement or
alteration is not Tenant's pursuant to Sections 6.1.3, 6.1.4 or 6.2.5, Landlord
shall make such required improvement or alteration.
5.7 Hazardous Waste Representation and Covenants. Landlord has previously
delivered to Tenant reports dated December 15, 1995 and April 10, 1998 by Xxxxx
Associates, Inc. and Dames & Xxxxx respectively with respect to certain
environmental conditions at the Property and a Phase I and Downgradient Property
Status Report of Xxxxx & Xxxxxxx dated August 1, 1997 with respect to 00
Xxxxxxxx Xxxxxx. So long as the condition requiring removal or remediation of
Hazardous Materials is not caused by Tenant or any party for whom Tenant is
responsible, Landlord shall, in a manner that complies with all applicable
Environmental Laws, perform or cause others to perform all remediation necessary
to cause the Property to comply with Environmental Laws. Landlord shall
indemnify and defend (with counsel reasonably acceptable to Tenant) Tenant from
any liability for fines or penalties arising from or related to a
-22-
breach by Landlord of the forgoing representations and agreements of Landlord
(including also costs incurred to avoid the imposition of, or to discharge, any
lien on the Property arising from any such breach) and from any liability for
costs of removing or remediating Hazardous Materials which Landlord is obligated
to remediate pursuant to this paragraph.
5.8 Indemnification. Subject to all limitations, waivers, exclusions and
conditions contained in this Lease (each of which shall control in the event of
any conflict or inconsistency with this Section 5.8), Landlord shall defend and
indemnify Tenant and its directors, officers, agents and employees against and
from any and all claims, liabilities or penalties asserted by or on behalf of
any third party on account of personal injury arising out of the negligence or
other wrongful conduct of Landlord or its agents, contractors or employees
during the term of this Lease. In case of any action or proceeding brought
against Tenant by reason of any such claim, Landlord, upon notice from Tenant,
shall resist or defend such action or proceeding and employ counsel therefor
reasonably satisfactory to Tenant. Notwithstanding the foregoing in no event
shall this Section 5.8 require Landlord to indemnify or defend Tenant or its
employees or Tenant's agents or their employees against any loss, cost, damage,
liability, claim, or expense to the extent arising out of the negligence or
misconduct of Tenant or its employees or contractors or Tenant's agents or their
employees.
ARTICLE 6
Tenant's Additional Covenants
6.1 Affirmative Covenants. Tenant shall do the following:
6.1.1 Perform Obligations. Tenant shall perform promptly all of the
obligations of Tenant set forth in this Lease; and pay when due the Annual Fixed
Rent and Additional Rent and all other amounts which by the terms of this Lease
are to be paid by Tenant.
6.1.2 Use. Tenant shall, during the term of this Lease, use the
Premises only for the Permitted Uses and from time to time, procure and
maintain, and at Landlord's request provide to Landlord copies of, all licenses
and permits necessary therefor and for any other use or activity conducted at
the Premises, at Tenant's sole expense. Tenant shall also provide to Landlord
access to all Material Safety Data Sheets on any Hazardous Materials in the
Premises for which Tenant or its agents are responsible.
6.1.3 Repair and Maintenance. Except for Landlord's obligation under
Section 5.1.4, Tenant shall, during the term of this Lease, maintain the
Premises in neat and clean order and condition, contract for daily cleaning and
routine pest control services for the Premises, and perform all repairs to the
Premises and all fixtures, systems, and equipment therein (including Tenant's
equipment and other personal property) as are necessary to keep them in good and
clean working order, appearance and condition and consistent with other premises
in first-class buildings used for the Permitted Uses, reasonable use and wear
thereof and damage by fire or by unavoidable casualty only excepted and shall
replace any damaged or broken glass in windows and doors of the Premises (except
glass in the exterior walls of the Building) with glass of the same quality as
that damaged or broken.
-23-
Tenant shall secure and pay for, keep in full force and effect and
enforce, contracts with appropriate and reputable service providers (such
contracts and providers to be approved in advance by Landlord) providing for
regular maintenance of any ventilating and air-conditioning systems or
components servicing the Premises exclusively and copies of such contracts and
service call requests and invoices shall be furnished to Landlord upon request.
Tenant shall keep any garbage, trash, rubbish or other refuse in
vermin-proof containers within the interior of the Premises until removed, and
shall dispose of such refuse in properly sealed bags placed in dumpsters
provided and emptied by Tenant's trash removal contractor at Tenant's sole
expense.
Landlord shall have no obligation to collect or dispose of any (a)
radioactive, volatile, highly flammable, explosive of toxic materials, (b)
needles, syringes, lancets, similar sharp objects or contaminated wares, (c)
human or animal tissue or products, or (d) any other Hazardous Materials, any
item identified in clauses (a) through (d), above, hereinafter referred to as
"Excepted Waste". Tenant agrees that title to and liability for any Excepted
Waste from the Premises shall remain with Tenant, even if Landlord collects
and/or disposes of any such Excepted Waste.
6.1.4 Compliance with Law. Tenant shall, during the term of this
Lease, make all repairs, alterations, additions or replacements to the Premises
required by any law or ordinance or any order or regulation of any public
authority; keep the Premises safe and equipped with all safety appliances so
required; and comply with, and perform all repairs, alterations, additions or
replacements required by, the orders and regulations of all governmental
authorities with respect to zoning, building, fire, health and other codes,
regulations, ordinances or laws applicable to the Premises or other portions of
the Property and arising out of any use being conducted in or on the Premises or
arising out of any work performed by Tenant, except that Tenant may (but only so
long as (i) Landlord shall not be subject to any fine or charge, (ii) neither
the Property nor any portion thereof shall be subject to being condemned or
vacated and (iii) neither the Property nor any portion thereof shall be subject
to any lien or encumbrance) defer compliance so long as the validity of any such
law, ordinance, order or regulation shall be contested by Tenant in good faith
and by appropriate legal proceedings, if Tenant first gives Landlord assurance
or security against any loss, cost or expense on account thereof in form and
amount acceptable to Landlord. For clarity, Tenant shall not be responsible for
compliance with any such laws, ordinances or regulations under this Section
6.1.4 unless required (I) due to Tenant's alterations or repairs or Tenant's
particular manner of use of the Premises (as opposed to office operations,
generally) or (II) due to the misconduct or negligence of Tenant or any agent,
employee or contractor of Tenant.
6.1.5 Indemnification. Tenant shall neither hold, nor attempt to
hold, Landlord or its employees or Landlord's agents or their employees liable
for, and Tenant shall indemnify and hold harmless Landlord, its employees and
Landlord's agents and their employees (collectively, the "Landlord Indemnitees")
from and against, any and all demands, claims, causes of action, fines,
penalties, damage, liabilities, judgments and expenses (including, without
limitation, attorneys' fees) incurred in connection with or arising from: (i)
the use or occupancy or manner of use or occupancy of the Premises by Tenant or
any person claiming under Tenant; (ii) any matter occurring on the Premises
during the term; (iii) any acts, omissions or negligence of Tenant or any
-24-
person claiming under Tenant, or the contractors, agents, employees, invitees or
visitors of Tenant or any such person; (iv) any breach, violation or
nonperformance by Tenant or any person claiming under Tenant or the employees,
agents, contractors, invitees or visitors of Tenant or any such person of any
tern, covenant or provision of this Lease or any law, ordinance or governmental
requirement of any kind for which compliance is not the responsibility of the
Landlord pursuant to this Lease; (v) claims of brokers or other persons for
commissions or other compensation arising out of any actual or proposed sublease
of any portion of the Premises or assignment of Tenant's interest under this
Lease, or Landlord's denial of consent thereto or exercise of any of Landlord's
other rights under Section 6.2.1; and (vi) any injury or damage to the property
of Tenant, its employees, agents, contractors, invitees, visitors or any other
person entering upon the Property under the express or implied invitation of
Tenant (except to the extent arising from or related to the willful misconduct
or gross negligence of the Landlord Indemnitees). If any action or proceeding is
brought against the Landlord Indemnitees by reason of any such claim, Tenant,
upon notice from Landlord, shall defend the same, at Tenant's expense, with
counsel reasonably satisfactory to Landlord. Notwithstanding the foregoing in no
event shall this Section 6.1.5 require Tenant to indemnify or defend the
Landlord Indemnitees against any loss, cost, damage, liability, claim, or
expense to the extent arising out of the gross negligence or willful misconduct
of Landlord or its employees or Landlord's agents or their employees or for any
event for which Landlord is to indemnify Tenant pursuant to Section 5.7 or 5.8,
nor shall this Section 6.1.5 require Tenant to perform any obligation for which
Landlord is expressly responsible under this Lease.
6.1.6 Landlord's Right to Enter. Tenant shall, during the term of
this Lease, permit Landlord and its agents and invitees to enter into and
examine the Premises at reasonable times and to show the Premises to prospective
lessees, lenders, partners and purchasers and others having a bonafide interest
in the Premises, and to make such repairs, alterations and improvements required
or permitted to be made by this Lease and to perform such testing and
investigation as Landlord shall reasonably determine to make or perform, and,
during the last six (6) months prior to the expiration of this Lease, to keep
affixed in suitable places notices of availability of the Premises. In all cases
except instances posing an imminent threat to life or property, and except for
any entry pursuant to the performance of Landlord's routine obligations under
Article 5, (i) Landlord shall give Tenant reasonable notice prior to making any
entry onto the Premises, provided, however, notwithstanding Section 10.1 to the
contrary, such notice may be made orally, and (ii) access to lab space shall be
undertaken only with a Tenant escort so long as Tenant shall make such escort
available at the time such access is requested.
6.1.7 Personal Property at Tenant's Risk. Tenant shall, during the
term of this Lease keep, at the sole risk and hazard of Tenant, all of the
furnishings, fixtures, equipment, effects and property of every kind, nature and
description of Tenant and of all persons claiming by, through or under Tenant
which may be on the Property, and if the whole or any part thereof shall be
lost, destroyed or damaged by fire, water or otherwise, or by the leakage or
bursting of water pipes, steam pipes, or other pipes, by theft or from any other
cause, Tenant shall hold harmless and indemnify Landlord from and against any
and all injury, loss, damage or liability to Tenant or to any other person or
entity arising out of said loss or damage, except to the extent such loss or
damage is caused by the gross negligence or willful misconduct of Landlord or
its employees or agents.
6.1.8 Payment of Landlord's Cost of Enforcement. Tenant shall pay on
demand
-25-
Landlord's expenses, including reasonable attorneys' fees, incurred in enforcing
any obligation of Tenant under this Lease or in curing any default by Tenant
under this Lease as provided in Section 8.5.
6.1.9 Yield Up. Tenant shall, at the expiration or earlier
termination of the term of this Lease, surrender all keys to the Premises;
remove all of its personal property in the Premises and any equipment and
fixtures installed in the Premises by Tenant (collectively, "Equipment"), except
to the extent Landlord may require such Equipment to be surrendered to Landlord;
remove such installations (including wiring and cabling wherever located),
alterations, improvements and Equipment made (or if applicable, restore any
items removed) or installed by or on behalf of Tenant as Landlord may request
wherever located and all of Tenant's signs; repair all damage caused by such
removal; and vacate and yield up the Premises (including all installations and
improvements or Equipment made or installed by or on behalf of Tenant except as
Landlord shall request Tenant to remove), broom clean and in the same good order
and repair in which Tenant is obliged to keep and maintain the Premises by the
provisions of this Lease. If Landlord so requests, Tenant, at its sole cost and
expense, shall properly cap or seal its wiring and cabling (wherever located) at
each end, properly label such wiring and cabling for future use, and surrender
such wiring and cabling in a good and safe condition on or before the earlier of
(i) the expiration or earlier termination of the term of this Lease, or (ii) the
date on which Tenant discontinues the use of such wiring and cabling.
Notwithstanding the preceding provisions of this Section 6.1.9, except for
cabling, which Tenant shall remove if Landlord does not require the same to be
sealed and surrendered as hereinabove provided, Tenant shall not be required to
remove [any Leasehold Improvement Work except as may be determined by Landlord
at the time of approval of Tenant's Plans or] alterations made by Tenant if (i)
Tenant's request for Landlord's consent to make such alterations (or Tenant's
notice of alterations which do not require Landlord's consent hereunder),
contains a statement in capital letters in not less than 14 point type advising
Landlord that Landlord shall be deemed to have waived its right to require
removal of such alterations at the end of the term unless Landlord, at the time
Landlord gives its consent (or within thirty (30) days after receiving notice of
alterations not requiring Landlord's consent), notifies Tenant that removal at
the end of the term is required, and (ii) Landlord does not so notify Tenant.
Any property no so removed shall be deemed abandoned and may be removed and
disposed of by Landlord in such manner as Landlord shall terminate and Tenant
shall pay Landlord the entire cost and expense incurred by it in effecting such
removal and disposition and in making any incidental repairs and replacements to
the Premises and for use and occupancy during the period after the expiration or
earlier termination of the term of this Lease and prior to the performance by
Tenant of its obligations under this Subsection 6.1.9.
In addition, Tenant shall, at its sole cost and expense, (i) provide
Landlord with an Environmental Report (as hereinafter defined) dated within
thirty (30) days of the expiration or earlier termination of the term of this
Lease (the "Termination Date") certifying that, subject to customary limitations
and standards, the Premises and any areas which may contain any property of
Tenant or any generator used by Tenant ("Ancillary Areas") do not contain any
hazardous, radioactive or biological materials brought to the Property by
Tenant, and (ii) obtain and provide to Landlord a termination as of the
Termination Date of any licenses or permits granted by governmental authorities
to Tenant with respect to the Premises and the Ancillary Areas as
-26-
Landlord shall require. An "Environmental Report" shall be a report of an
industrial hygienist, or other qualified professional, reasonably satisfactory
to Landlord for which all testing shall have been performed not later than
thirty (30) days prior to the date of such report and which shall be the
standard of diligence at the time for surrender of similar space used for
similar purposes, together with any additional investigation and report which
would customarily follow any discovery contained in such initial report.
6.1.10 Rules and Regulations. Tenant shall, during the term of this
Lease, observe and abide by the Rules and Regulations of the Building set forth
as Exhibit B, as the same may from time to time be reasonably amended, revised
or supplemented with reasonable prior notice to Tenant (the "Rules and
Regulations"). Tenant shall further be responsible for compliance with the Rules
and Regulations by the employees, servants, agents and visitors of Tenant. The
failure of Landlord to enforce any of the Rules and Regulations against Tenant,
or against any other tenant or occupant of the Building, shall not be deemed to
be a waiver of such Rules and Regulations. Tenant shall be liable for all
injuries or damages sustained by Landlord or Landlord's agents or by other
tenants, occupants or invitees of the Building arising by reason of any breach
of the Rules or Regulations by Tenant or by Tenant's agents or employees.
6.1.11 Estoppel Certificate. Tenant shall, within ten (10) days'
following written request by Landlord, execute, acknowledge and deliver to
Landlord a statement in form satisfactory to Landlord in writing certifying that
this Lease is unmodified and in full force and effect and that Tenant has no
defenses, offsets or counterclaims against its obligations to pay the Annual
Fixed Rent and Additional Rent and any other charges and to perform its other
covenants under this Lease (or, if there have been any modifications, that this
Lease is in full force and effect as modified and stating the modifications and,
if there are any defenses, offsets or counterclaims, setting them forth in
reasonable detail), the dates to which the Annual Fixed Rent and Additional Rent
and other charges have been paid, and any other matter pertaining to this Lease.
Any such statement delivered pursuant to this subsection 6. 1.11 may be relied
upon by any prospective purchaser or mortgagee of the Property, or any
prospective assignee of such mortgage.
6.1.12 Landlord's Expenses For Consents. Tenant shall reimburse
Landlord, as Additional Rent, promptly on demand for all reasonable legal,
engineering and other professional services expenses incurred by Landlord in
connection with all requests by Tenant for consent or approval hereunder.
6.1.13 Financial Information. Tenant shall, from and after the Date
of this Lease and thereafter throughout the term of this Lease, provide Landlord
with such information as to Tenant's financial condition and/or organizational
structure as Landlord or the holder of any mortgage of the Property reasonably
requires, within fifteen (15) days of request. Landlord shall not, except as may
be required by law, disclose such information except to such parties as may be
appropriate in connection with the management, operation or actual or potential
financing or sale of the Premises, all of whom Landlord shall instruct to keep
such information confidential.
6.2 Negative Covenants. Tenant shall not do the following.
6.2.1 Assignment and Subletting. Tenant shall not assign, mortgage,
pledge, hypothecate, encumber or otherwise transfer this Lease or any interest
herein or sublease (which
-27-
term shall be deemed to include the granting of concessions and licenses and the
like) all or any part of the Premises or suffer or permit this Lease or the
leasehold estate hereby created or any other rights arising under this Lease to
be assigned, transferred, mortgaged, pledged, hypothecated or encumbered, in
whole or in part, whether voluntarily, involuntarily or by operation of law, or
permit the use or occupancy of the Premises by anyone other than Tenant, or the
Premises to be offered or advertised for assignment or subletting, except as
hereinafter provided.
Notwithstanding the foregoing, Tenant may, without the need for Landlord's
consent, but only upon not less than ten (10) days prior notice to Landlord,
assign its interest in this Lease (a "Permitted Assignment") to (i) any entity
which shall be a successor to Tenant either by merger or consolidation (a
"Merger") or to a purchaser of all or substantially all of Tenant's assets in
either case provided the successor or purchaser shall have a tangible net worth,
after giving effect to the transaction, of not less than the greater of the net
worth of Tenant named in Section 1.1 as of the Date of this Lease or the net
worth of Tenant named in Section 1.1 immediately prior to such Merger or sale
(the "Required Net Worth") or (ii) any entity (an "Affiliate") which is a direct
or indirect subsidiary or parent (or a direct or indirect subsidiary of a
parent) of the named Tenant set forth in Section 1. 1, in either case of (i) or
(ii) only so long as (I) the principal purpose of such assignment is not the
acquisition of Tenant's interest in this Lease (except if such assignment is
made for a valid intracorporate business purpose to an Affiliate) and is not
made to circumvent the provisions of this Section 6.2.1, (II) except if pursuant
to a Merger permitted by clause (i) above, Tenant shall, contemporaneously with
such assignment, provide Landlord with a fully executed counterpart of any such
assignment, which assignment shall comply with the provisions of this Section
6.2.1 and shall include an agreement by the assignee in form reasonably
satisfactory to Landlord, to be bound by all of the terms of this Lease, (III)
in the case of an actual or deemed assignment pursuant to clause (i), Tenant
shall provide Landlord, not less than ten (10) days in advance of any such
assignment, evidence reasonably satisfactory to Landlord of the Required Net
Worth of the successor or purchaser, and (IV) there shall not be a Default of
Tenant at the effective date of such assignment. Tenant shall also be permitted,
without the need for Landlord's consent, but only upon not less than ten (10)
days prior notice to Landlord, to enter into any sublease (a "Permitted
Sublease") with any Affiliate provided that such sublease shall expire upon any
event pursuant to which the sublessee thereunder shall cease to be an Affiliate.
Any assignment to an Affiliate shall provide that it may, at Landlord's
election, be terminated and deemed void if during the term of this Lease such
assignee or any successor to the interest of Tenant hereunder shall cease to be
an Affiliate.
In the event that Tenant shall intend to enter into any sublease or
assignment other than a Permitted Sublease or Permitted Assignment, then Tenant
shall, not sooner than one hundred twenty (120) days prior to the proposed
commencement of such sublease or assignment, give Landlord notice of such
intent, identifying the proposed subtenant or assignee, all of the terms and
conditions of the proposed sublease or assignment and such other information as
the Landlord may reasonably request. In such case Landlord may elect (a) to
terminate the term of this Lease if Tenant intends to assign this Lease, or to
sublease (including expansion options) all or substantially all of the Premises
for a term (including extension options) of more than half of the remaining term
hereof or (b) to exclude from the Premises, for the term of such proposed
sublease, the portion thereof to be sublet if the conditions set forth in (a) do
not prevail, by giving notice to Tenant of such election not later than thirty
(30) days after receiving notice of such intent from Tenant. If Landlord shall
give such notice within such thirty (30) day period, upon the later to
-28-
occur of (A) the proposed date of commencement of such proposed sublease or
assignment, or (B) the date which is thirty (30) days after Landlord's notice,
the term of this Lease shall terminate or the Premises shall be reduced to
exclude the portion of the Premises intended for subletting, in which case
Annual Fixed Rent and Tenant's Percentage shall be correspondingly reduced and
Tenant shall pay Landlord's cost to install any new demising walls and common
area corridors and lobbies. If Landlord shall give its consent, Tenant may enter
into such sublease or assignment on the terms and conditions set forth in such
notice from Tenant within one hundred twenty (120) days of the initially
proposed sublease commencement date. If Tenant shall not enter into such
sublease or assignment within such period and shall still desire to enter into
any sublease or assignment, or if Tenant shall change the terms and conditions
thereof following the date of Tenant's notice to Landlord; the first sentence of
this paragraph shall again become applicable.
If Landlord shall not elect to exclude from the Premises the area to be
sublet or to terminate the term of this Lease pursuant to the preceding
paragraph, then Landlord shall not unreasonably withhold its consent to the
applicable sublease, provided that, in addition to any other grounds for
withholding of consent, Landlord may withhold its consent if in Landlord's good
faith judgment: (i) the proposed subtenant does not have the financial strength
to perform its obligations under the proposed sublease; (ii) the business and
operations of the proposed subtenant are not compatible with the business and
operations being conducted by any other tenant in the Building or is otherwise
inconsistent with Landlord's commitments to any other occupant of the Building;
(iii) the proposed subtenant is a business competitor of Landlord or is an
affiliate of a business competitor of Landlord; (iv) at the time of the proposed
subleasing Landlord is able to meet the space requirements of Tenant's proposed
subtenant by leasing available space in the Building to such person or entity;
(v) the proposed subtenant is an entity, or is affiliated with any entity, which
shall have entered into negotiation with Landlord for space in the Building
within the preceding four (4) months; or (vi) the use of the Premises or the
Building by the proposed subtenant or assignee would increase Operating Costs,
require any alterations to the Building to cause the Building to comply with
applicable laws, or otherwise cause Landlord to incur any additional cost or
expense.
If this Lease is assigned or if the Premises or any part thereof are
sublet (or occupied by any party other than Tenant and its employees) Landlord
may collect the rents from such assignee, subtenant or occupant, as the case may
be, and apply the net amount collected to the Annual Fixed Rent and Additional
Rent herein reserved, but no such collection shall be deemed a waiver of the
provisions set forth in the first paragraph of this Subsection 6.2.1, the
acceptance by Landlord of such assignee, subtenant or occupant, as the case may
be, as a tenant, or a release of Tenant from the future performance by Tenant of
its covenants, agreements or obligations contained in this Lease.
Any sublease of all or any portion of the Premises shall provide that it
is subject and subordinate to this Lease and to the matters to which this Lease
is or shall be subject or subordinate, that other than the payment of Annual
Fixed Rent and Additional Rent due pursuant to Sections 4.1, 4.2.1 and 4.2.2 or
any obligation relating solely to those portions of the Premises which are not
part of the subleased premises, the subtenant shall comply with and be bound by
all of the obligations of Tenant hereunder, that unless Landlord waives such
prohibition, the subtenant may not enter into any sub-sublease, sublease
assignment, license or any other agreement granting any right of occupancy of
any portion of the subleased premises; and that Landlord shall be an
-29-
express beneficiary of any such obligations, and that in the event of
termination of this Lease or reentry or dispossession of Tenant by Landlord
under this Lease, Landlord may, at its option, take over all of the right, title
and interest of Tenant, as sublessor under such sublease, and such subtenant
shall, at Landlord's option, attorn to Landlord pursuant to the then executory
provisions of such sublease, except that neither Landlord nor any mortgagee of
the Property, as holder of a mortgage or as Landlord under this Lease if such
mortgagee succeeds to that position, shall (a) be liable for any act or omission
of Tenant under such sublease, (b) be subject to any credit, counterclaim,
offset or defense which theretofore accrued to such subtenant against Tenant, or
(c) be bound by any previous modification of such sublease unless consented to
by Landlord and such mortgagee or by any previous prepayment of more than one
(1) month's rent, (d) be bound by any covenant of Tenant to undertake or
complete any construction of the Premises or any portion thereof, (e) be
required to account for any security deposit of the subtenant other than any
security deposit actually received by Landlord, (f) be bound by any obligation
to make any payment to such subtenant or grant any credits unless specifically
agreed to by Landlord and such mortgagee, (g) be responsible for any monies
owing by Landlord to the credit of Tenant or (h) be required to remove any
person occupying the Premises or any part thereof; and such sublease shall
provide that the subtenant thereunder shall, at the request of Landlord, execute
a suitable instrument in confirmation of such agreement to attorn. To enable
Landlord to confirm that any sublease which Tenant shall desire to enter into
shall comply with the provisions of this Section 6.2.1 and/or otherwise be
acceptable to Landlord in accordance with this Section 6.2.1, Tenant shall
submit the final form of sublease or the executed version subject to Landlord's
consent to Landlord not less than thirty (30) days prior to its execution. The
provisions of this paragraph shall not be deemed a waiver of the provisions set
forth in the first paragraph of this Subsection 6.2.1.
Tenant shall not enter into, nor shall it permit any person having an
interest in the possession, use, occupancy or utilization of any part of the
Premises to enter into, any sublease, license, concession, assignment or other
agreement for use, occupancy or utilization of the Premises (i) which provides
for rental or other compensation based on the income or profits derived by any
person or on any other formula such that any portion of such sublease rental, or
other consideration for a license, concession, assignment or other occupancy
agreement, would fail to qualify as "rents from real property" within the
meaning of Section 856(d) of the Internal Revenue Code or any similar or
successor provision thereto, or would otherwise disqualify Landlord for
treatment as a real estate investment trust under Sections 856-869 of the
Internal Revenue Code, (ii) under which fifty percent (50%) or more of the total
rent or other compensation received by Tenant is attributable to personal
property or (iii) which would otherwise be subject to the prohibitions of
Section 406 of ERISA or result in imposition of any tax pursuant to Section 511
or Section 4975 of the Internal Revenue Code; and any such purported lease,
sublease, license, concession or other agreement shall be absolutely void and
ineffectual as a conveyance of any right or interest in the possession, use,
occupancy or utilization of such part of the Premises.
No subletting or assignment shall in any way impair the continuing primary
liability of Tenant hereunder, and no consent to any subletting or assignment in
a particular instance shall be deemed to be a waiver of the obligation to obtain
the Landlord's written approval in the case of any other subletting or
assignment. The joint and several liability of Tenant named herein and any
immediate and remote successor in interest of Tenant (by assignment or
otherwise), and the due performance of the obligations of this Lease on Tenant's
part to be performed or observed, shall not in any way be discharged, released
or impaired by any (a) agreement which modifies any of the
-30-
rights or obligations of the parties under this Lease, (b) stipulation which
extends the time within which an obligation under this Lease is to be performed,
(c) waiver of the performance of an obligation required under this Lease, or (d)
failure to enforce any of the obligations set forth in this Lease. No
assignment, subletting or occupancy shall affect the Permitted Uses. Any
subletting, assignment or other transfer of Tenant's interest in this Lease in
contravention of this Subsection 6.2.1 shall be voidable at Landlord's option.
Tenant shall not occupy any space in the Building (by assignment, sublease or
otherwise) other than the Premises.
If the rent and other sums (including, without limitation, all monetary
payments plus the reasonable value of any services performed or any other thing
of value given by any assignee or subtenant in consideration of such assignment
or sublease), either initially or over the term of any assignment or sublease
(other than a Permitted Assignment of a Permitted Sublease), payable by such
assignee or subtenant exceed the Annual Fixed Rent plus Additional Rent called
for hereunder with respect to the space assigned or sublet, Tenant shall pay
fifty percent (50%) of such excess to Landlord, as Additional Rent, payable
monthly at the time for payment of Annual Fixed Rent, provided that the
amortized portion of the following "Transfer Expenses" paid by Tenant in
connection with such assignment or sublease may be deducted from the monthly
payments of any such excess: (i) the cost of (including architectural and
construction management fees for) alterations or improvements made by Tenant to
the Premises in order to consummate an assignment or to the portion of Premises
that is subleased in order to consummate a sublease, (ii) reasonable brokerage
commissions or fees, and (iii) reasonable attorneys fees. Any such Transfer
Expenses shall be amortized in equal monthly installments over the term of the
assignment or sublease and shall be verified by written documentation reasonably
satisfactory to Landlord within sixty (60) days after the date of delivery of
possession to the assignee or sublessee; and the amortized portion shall be the
Transfer Expenses divided by the number of months of the assignment or sublease.
Nothing in this paragraph shall be deemed to abrogate the provisions of this
Subsection 6.2.1 and Landlord's acceptance of any sums pursuant to this
paragraph shall not be deemed a granting of consent to any assignment of the
Lease or sublease of all or any portion of the Premises.
6.2.2 Nuisance. Tenant shall not injure, deface or otherwise harm
the Premises; nor commit any nuisance; nor permit the emission of any
objectionable noise or odor; nor make, allow or suffer any waste; nor make any
use of the Premises which is improper, offensive or contrary to any law or
ordinance or which will invalidate or increase the premiums for any of
Landlord's insurance (above that which would prevail generally for premises used
for pharmacological research and development purposes) or which is liable to
render necessary any alteration or addition to the Building.
6.2.3 Floor Load, Heavy Equipment. Tenant shall not place a "live"
load upon any floor of the Premises exceeding 100 pounds per square foot.
Landlord reserves the right to prescribe the weight and position of all heavy
business machines and equipment, including safes, which shall be placed so as to
distribute the weight. Business machines and mechanical equipment which cause
vibration or noise shall be placed and maintained by Tenant at Tenant's expense
in settings sufficient to absorb and prevent vibration, noise and annoyance.
Tenant shall not move any safe, heavy machinery, heavy equipment, freight,
construction materials or fixtures into or out of the Premises without
Landlord's prior consent which consent may not be withheld, conditioned or
delayed, provided that Landlord's consent may include a requirement to provide
-31-
insurance naming Landlord, and the holder of any mortgage affecting the
Property, as additional insureds, with such coverage and in such amount as
Landlord reasonably requires. If any such safe, machinery, heavy equipment,
freight, or fixtures requires special handling, Tenant agrees to employ only
persons holding a master rigger's license to do said work, and that all work in
connection therewith shall comply with applicable laws and regulations. Any such
moving shall be at the sole risk and hazard of Tenant. Tenant shall schedule
such moving at such times as Landlord shall reasonably designate.
6.2.4 Electricity. Tenant shall not connect to the electrical
distribution system serving the Premises a total or peak load exceeding the
lesser of the capacity of such system or the maximum load permitted from time to
time under applicable governmental regulations. The capacity of the electrical
distribution system serving the Premises shall be the lesser of (a) the capacity
of the branch of the system serving the Premises exclusively or (b) Tenant's
Percentage of the capacity of the system serving the entire Building.
6.2.5 Installation, Alterations or Additions. Tenant shall not make
any installations, alterations, additions or improvements (collectively and
individually referred to in this paragraph as "work") in, to or on the Premises
nor permit the making of any holes in the walls, partitions, ceilings or floors
without on each occasion obtaining the prior consent of Landlord, and then only
pursuant to plans and specifications approved by Landlord in advance in each
instance. Landlord's consent and approval shall not be unreasonably withheld or
delayed with respect to work which equals or exceeds the typical level of
improvements in the Building in quality and does not adversely affect the
plumbing, heating, ventilating, air-conditioning, mechanical, electrical or
life-safety systems of the Building, does not adversely affect the structural
elements of the Building, is not visible from outside of the Premises and shall
not materially increase Taxes of Operating Costs nor require Landlord to perform
any work to the Property, and Tenant need not obtain Landlord's consent to
install readily removable signs, display boards, floor and wall coverings, work
stations and shelves within the Premises provided Tenant shall give Landlord
prior notice thereof, the same are not visible from the common areas of the
Building or Property and any such work shall be scheduled at a time reasonably
acceptable to Landlord. All work to be performed to the Premises by Tenant shall
(i) be performed in a good and workmanlike manner by contractors reasonably
approved in advance by Landlord and in compliance with the provisions of Exhibit
C and all applicable zoning, building, fire, health and other codes,
regulations, ordinances and laws, (ii) be made at Tenant's sole cost and expense
and at such times and in such a manner as Landlord may from time to time
reasonably designate, and (iii) be free of liens and encumbrances and become
part of the Premises and the property of Landlord without being deemed
additional rent for tax purposes, Landlord and Tenant agreeing that Tenant shall
be treated as the owner of the work for tax purposes until the expiration or
earlier termination of the term hereof, subject to Landlord's rights pursuant to
Section 6.1.9 to require Tenant to remove the same at or prior to the expiration
or earlier termination of the term hereof and, to the extent Landlord shall make
such election, title thereto shall remain vested in Tenant at all times. Tenant
shall pay promptly when due the entire cost of any work to the Premises so that
the Premises, Building and Property shall at all times be free of liens, and, at
Landlord's request (but only for work, which together with any related work,
shall exceed $100,000 in cost), Tenant shall furnish to Landlord a bond or other
security acceptable to Landlord assuring that any such work will be completed in
accordance with the plans and specifications theretofore approved by Landlord
and assuring that the Premises will remain free
-32-
of any mechanics' lien or other encumbrances that may arise out of such work.
Prior to the commencement of any such work, and throughout and until completion
thereof, Tenant shall maintain, or cause to be maintained, the insurance
required by Exhibit D, all with coverage limits as stated therein or such higher
limits as shall be reasonably required by Landlord. In addition, Tenant shall
save Landlord harmless and indemnified from all injury, loss, claims or damage
to any person or property occasioned by or arising out of such work. Whenever
and as often as any mechanic's or materialmen's lien shall have been filed
against the Property based upon any act of Tenant or of anyone claiming through
Tenant, Tenant shall within three (3) days of notice from Landlord to Tenant
take such action by bonding, deposit or payment as will remove or satisfy the
lien. Tenant shall, upon request of Landlord, execute and deliver to Landlord a
xxxx of sale covering any work or Equipment Tenant shall be required to
surrender hereunder.
Tenant shall not, at any time, directly or indirectly, employ or permit
the employment of any contractor, mechanic or laborer in the Premises, if such
employment will interfere or cause any conflict with other contractors,
mechanics or laborers engaged in the construction, maintenance or operation of
the Building by Landlord, Tenant or others. In the event of any such
interference or conflict, Tenant, upon demand of Landlord, shall cause all
contractors, mechanics or laborers causing such interference or conflict to
leave the Building immediately.
6.2.6 Intentionally Deleted.
6.2.7 Signs. Tenant shall not paint or place any signs or place any
curtains, blinds, shades, awnings, aerials, or the like, visible from outside
the Premises. Landlord shall not unreasonably withhold consent for signs or
lettering in the second floor lobby provided such signs conform to building
standards adopted by Landlord. Landlord shall maintain a tenant directory in the
lobby of the Building in which will be placed Tenant's name and the location of
the Premises in the Building.
So long as (i) this Lease is still in full force and effect and (ii) the
named Tenant (the "Named Tenant") as set forth in Section 1.1 (or any successor
by merger, or any Affiliate) shall actually occupy at least seventy percent
(70%) of the Premises (the "Sign Conditions"), Tenant shall have the
non-exclusive right, subject to applicable legal requirements and the terms of
this Lease, at Tenant's sole cost and expense, to install and maintain a single
building-mounted sign (hereinafter, "Tenant's Sign") on the Building and to
maintain a panel on the Building's sign monument. The size, construction,
location and design of Tenant's Sign shall be subject to Landlord's approval,
not to be unreasonably withheld. Without limiting the foregoing, Landlord may
refuse to approve any sign that is not consistent with the architecture and
general appearance of the Building and Property, or which is otherwise
inconsistent with first-class office building signage. Tenant's Sign and its
monument sign shall be expressly for purposes of identifying the Named Tenant
and shall not include the name of any other person or entity. Tenant shall
obtain, at its expense, all permits and approvals required for the installation
of Tenant's Sign prior to the installation thereof (but shall not be permitted
to seek any zoning or similar relief for Tenant's Sign without Landlord's
consent, which may be withheld in Landlord's sole discretion), and shall keep
all such permits and approvals in full force and effect throughout the term.
Tenant shall perform all maintenance and repairs to Tenant's Sign and its
monument sign required to keep them in good condition. The installation, repair,
maintenance and removal of Tenant's Sign and the monument sign shall be subject
to the provisions of Section 6.2.5 of this
-33-
Lease and Landlord's other reasonable requirements. Prior to the expiration or
earlier termination of the term of this Lease, and upon any event pursuant to
which the Sign Conditions cease to prevail, Tenant shall remove Tenant's Sign
(and all associated hardware) from the Building and shall fill all holes and
repair all damage caused by the installation of such sign or its removal.
6.2.8 Oil and Hazardous Materials. Except as permitted below, Tenant
shall not introduce on or transfer to the Premises or Property, any Hazardous
Materials (as hereinafter defined); nor dump, flush or otherwise dispose of any
Hazardous Materials into the drainage, sewage or waste disposal systems serving
the Premises or Property, nor generate, store, use, release, spill or dispose of
any Hazardous Materials in or on the Premises or the Property, or to transfer
any Hazardous Materials from the Premises to any other location. Except as
permitted below, Tenant shall not commit or suffer to be committed in or on the
Premises or Property any act which would require any reporting or filing of any
notice with any governmental agency pursuant to any statutes, laws, codes,
ordinances, rules or regulations, present or future, applicable to the Property
or to Hazardous Materials.
Notwithstanding the preceding paragraph, Tenant shall be permitted,
without the need for Landlord's prior consent, but provided Tenant first submits
to Landlord a list of all such Hazardous Materials (the "Listed Materials") and
all permits required therefore and thereafter shall provide to Landlord on an
annual basis Tenant's certification that all such permits have been renewed with
copies of such renewed permits and subject to the remaining conditions of this
Subsection 6.2.8, to introduce on or transfer to the Premises, generate, store,
use and dispose of Listed Materials in connection with the Permitted Uses
provided such activities shall be in compliance with all Environmental Laws and
any requirements of Landlord's insurer of which Tenant shall have been given
reasonable prior notice.
Tenant agrees that if it shall otherwise generate, store, release, spill,
dispose of or transfer to the Premises or Property any Hazardous Materials, it
shall forthwith remove the same, at its sole cost and expense, in the manner
provided by all applicable Environmental Laws (as hereinafter defined),
regardless of when such Hazardous Materials shall be discovered. Furthermore,
Tenant shall pay any fines, penalties or other assessments imposed by any
governmental agency with respect to any such Hazardous Materials and shall
forthwith repair and restore any portion of the Premises or Property which it
shall disturb in so removing any such Hazardous Materials to the condition which
existed prior to Tenant's disturbance thereof.
Tenant agrees to deliver promptly to Landlord any notices, orders or
similar documents received from any governmental agency or official concerning
any violation of any Environmental Laws or with respect to any Hazardous
Materials affecting the Premises or Property. In addition, Tenant shall, within
ten (10) days of receipt, accurately complete any questionnaires from Landlord
or other informational requests relating to Tenant's use of the Premises and, in
particular, to Tenant's use, generation, storage and/or disposal of Hazardous
Materials at, to, or from the Premises.
Tenant shall indemnify, defend (by counsel satisfactory to Landlord),
protect, and hold Landlord free and harmless from and against any and all
claims, or threatened claims, including without limitation, claims for death of
or injury to any person or damage to any property, actions, administrative
proceedings, whether formal or informal, judgments, damages, punitive damages,
-34-
liabilities, penalties, fines, costs, taxes, assessments, forfeitures, losses,
expenses, attorneys' fees and expenses, consultant fees, and expert fees that
arise from or are caused in whole or in part, directly or indirectly, by (i)
Tenant's use, analysis, storage, transportation, disposal, release, threatened
release, discharge or generation of Hazardous Materials to, in, on, under, about
or from the Premises, or (ii) Tenant's failure to comply with any Environmental
Laws. Tenant's obligations hereunder shall include, without limitation, and
whether foreseeable or unforeseeable, all costs (including, without limitation,
capital, operating and maintenance costs) incurred in connection with any
investigation or monitoring of site conditions, repair, cleanup, containment,
remedial, removal or restoration work, or detoxification or decontamination of
the Premises, and the preparation and implementation of any closure, remedial
action or other required plans in connection therewith; provided however in no
event shall Tenant be required by this Section 6.2.8 to remediate any
contamination which shall have existed on the Property as of the Commencement
Date or which shall have migrated to the Property or been brought to the
Property by parties other than Tenant. For purposes of this Section 6.2.8 and
Section 6.1.9, any acts or omissions of Tenant, or its subtenants or assignees
or its or their employees, agents, or contractors (whether or not they are
negligent, intentional, willful or unlawful) shall be attributable to Tenant.
The term "Hazardous Materials" shall mean and include any oils, petroleum
products, asbestos, radioactive, biological, medical or infectious wastes or
materials, and any other toxic or hazardous wastes, materials and substances
which are defined, determined or identified as such in any Environmental Laws,
or in any judicial or administrative interpretation of Environmental Laws.
"Environmental Laws" shall mean any and all federal, state and municipal
statutes, laws, regulations, ordinances, rules, judgments, orders, decrees,
codes, plans, injunctions, permits, concessions, grants, franchises, licenses,
agreements or other governmental restrictions relating to the environment or to
emissions, discharges or releases of pollutants, contaminants, petroleum or
petroleum products, medical, biological, infectious, toxic or hazardous
substances or wastes into the environment including, without limitation, ambient
air, surface water, ground water or land, or otherwise relating to the
manufacture, processing, distribution, use, treatment, storage, disposal,
transport or handling of pollutants, contaminants, petroleum or petroleum
products, medical, biological, infectious, toxic or hazardous substances or
wastes or the cleanup or other remediation thereof.
ARTICLE 7
Casualty or Taking
7.1 Termination.
7.1.1 Termination by Landlord. In the event that the Premises or the
Building shall be destroyed or damaged by any material fire or other casualty or
shall be affected by any material taking by eminent domain or condemnation, then
the term of this Lease may be terminated at the election of Landlord. Such
election, which may be made notwithstanding the fact that Landlord's entire
interest may have been divested, shall be made by the giving of notice by
Landlord to Tenant within sixty (60) days after the date of the taking or
casualty. A fire or
-35-
other casualty or taking or condemnation shall be "material" if (i) the time to
repair shall exceed six (6) months from the date of the fire or other casualty
or (ii) the area affected by the fire or other casualty or the taking or
condemnation shall exceed fifteen percent (15%) of the Premises or Building, as
applicable, or (in the case of a taking) shall affect more than fifteen percent
(15%) of the parking spaces on the Property.
7.1.2 Termination by Tenant. In the event that the Premises or any
part of the Building required for the conduct of Tenant's business at the
Premises shall be taken by any public authority or for any public use or shall
be condemned by the action of any public authority, then the term of this Lease
may be terminated at the election of Tenant by the giving of notice to Landlord
within sixty (60) days after the date of the taking. In the event any material
part of the Premises or any part of the Building necessary for the conduct of
Tenant's business at the Premises shall be destroyed or damaged by fire or other
casualty (and Landlord has not elected to terminate the term of this Lease
pursuant to Section 7.1.1), then as soon as practicable after the occurrence of
such damage, Landlord shall give Tenant a notice (the "Restoration Notice")
advising Tenant whether or not Landlord intends to restore the Premises
(excluding any alterations made by Tenant) or such other portion of the Building
to a condition substantially the same as existed immediately prior to such
damage, and if Landlord intends to so restore, the time required to
substantially complete such work, as reasonably estimated by an architect or a
qualified general contractor selected by Landlord. If the Restoration Notice
indicates either that (a) Landlord shall not restore the Premises or Building as
provided above, or (b) the estimated time required for Landlord to substantially
complete such restoration work shall exceed two hundred ten (210) days from the
occurrence of such casualty damage, then Tenant may elect to terminate the term
of this Lease by giving notice to Landlord not later than thirty (30) days after
the date on which Landlord gives Tenant the Restoration Notice. Tenant may also
elect to terminate the term of this Lease if the Lease is not terminated and
Landlord shall fail to complete such restoration of the Premises or Building as
described in the Restoration Notice within the estimated repair period, as such
period is extended for delays not within Landlord's reasonable control (but not
to exceed an additional thirty (30) days). Any election by Tenant to terminate
the term of this Lease pursuant to the preceding sentence shall be made by
notice given to Landlord not later than thirty (30) days after the expiration of
the estimated repair period (as it may have been extended for delays beyond
Landlord's reasonable control). Notwithstanding the foregoing, Tenant shall have
no right to terminate the term of this Lease due to a fire or other casualty if
the cause thereof was due solely to the negligence or other wrongful conduct of
Tenant or any subtenant of Tenant or any agent, employee or contractor of Tenant
or its subtenant(s).
7.2 Restoration. If Landlord does not elect to so terminate, this Lease
shall continue in force and (so long as the damage is not caused by the
negligence or other wrongful act of Tenant or its employees, agents, contractors
or invitees) a just proportion of the Annual Fixed Rent reserved, according to
the nature and extent of the damages sustained by the Premises, shall be
suspended or abated until the Premises (excluding any improvements to the
Premises made at Tenant's expense), or what may remain thereof, shall be put by
Landlord in proper condition for use, which Landlord covenants to do with
reasonable diligence to the extent permitted by the net proceeds of insurance
recovered or damages awarded for such destruction, taking, or condemnation and
subject to zoning and building laws or ordinances then in existence. "Net
proceeds of insurance recovered or damages awarded" refers to the gross amount
of such insurance or damages actually made available to Landlord (and not
retained by any Superior
-36-
Lessor or Superior Mortgagee) less the reasonable expenses of Landlord incurred
in connection with the collection of the same, including without limitation,
fees and expenses for legal and appraisal services.
7.3 Award. Irrespective of the form in which recovery may be had by law,
all rights to damages or compensation for a taking by a public authority shall
belong to Landlord in all cases. Tenant hereby grants to Landlord all of
Tenant's rights to such damages and covenants to deliver such further
assignments thereof as Landlord may from time to time request. Nothing contained
herein shall be construed to prevent Tenant from prosecuting in any condemnation
proceedings a claim for relocation expenses.
7.4 Effect of Casualty or Taking on the Tax Excess and the Operating
Cost Excess. In the event of any taking, condemnation or damage by fire or
casualty affecting the Property whereby the term of this Lease shall not
terminate pursuant to the provisions of Section 7. 1, then for purposes of
determining the Operating Cost Excess or Tax Excess there shall be established
new Base Taxes and Base Operating Costs as hereinafter provided. Base Taxes
shall be a product of the initial Base Taxes as recited in Section 1.1
multiplied by a fraction, the numerator of which shall be the Taxes for the
first full Tax Year subsequent to the taking, condemnation or damage which
reflects the occurrence of such taking, condemnation or damage (the "Revised Tax
Year"), and the denominator of which shall be the Taxes for the full Tax Year
prior to such taking, condemnation or damage; and Base Operating Costs shall be
the product of the initial Base Operating Costs as recited in Section 1.1
multiplied by a fraction, the numerator of which shall be Operating Costs for
the first full Operating Year subsequent to such taking, condemnation or damage
which reflects the occurrence of such taking, condemnation or damage (the
"Revised Operating Year") and the denominator of which shall be the Operating
Costs for the full Operating Year prior to such taking, condemnation or damage.
The foregoing revisions shall be effective as of the first day of the Revised
Tax Year or the Revised Operating Year (as applicable). Effective as of the date
of any such taking, condemnation or damage, Tenant's Percentage shall be
adjusted appropriately to reflect the change, if any, in the rentable area of
the Premises and/or the rentable area of the Building.
ARTICLE 8
Defaults
8.1 Default of Tenant. (a) (I) If Tenant shall default in its
obligations to pay the Annual Fixed Rent or Additional Rent or any other charges
or amounts under this Lease when due or shall default in complying with its
obligations under Subsection 6.1.11 of this Lease and if any such default shall
continue for ten (10) days after notice from Landlord designating such default,
or (II) if as promptly as possible but in any event within thirty (30) days
after notice from Landlord to Tenant specifying any default or defaults other
than those set forth in clause (I) Tenant has not cured the default or defaults
so specified (or if such breach or default cannot be cured within said time,
then within such additional time (not to exceed an additional thirty (30) days)
as may be necessary if within said thirty (30) days Tenant has commenced and is
diligently pursuing the remedies necessary to cure such breach or default); or
(b) if any assignment shall be made by Tenant for the benefit of creditors; or
(c) if Tenant's leasehold interest shall be taken on execution; or (d) if a lien
or other involuntary encumbrance shall be filed against Tenant's
-37-
leasehold interest or Tenant's other property, including said leasehold
interest, and shall not be discharged within ten (10) days thereafter (or if
such lien cannot be discharged within said time, then within such additional
time (not to exceed an additional thirty (30) days) as may be necessary if
within said ten (10) days Tenant has commenced and is diligently pursuing the
remedies necessary to discharge such lien); or (e) if a petition shall be filed
by Tenant for liquidation, or for reorganization or an arrangement under any
provision of any bankruptcy law or code as then in force and effect; or (f) if
an involuntary petition under any of the provisions of any bankruptcy law or
code shall be filed against Tenant and such involuntary petition shall not be
dismissed within thirty (30) days thereafter; or (g) if a custodian or similar
agent shall be authorized or appointed to take charge of all or substantially
all of the assets of Tenant; or (h) if Tenant dissolves or shall be dissolved or
shall liquidate or shall adopt any plan or commence any proceeding, the result
of which is intended to include dissolution or liquidation; or (i) if any order
shall be entered in any proceeding by or against Tenant decreeing or permitting
the dissolution of Tenant or the winding up of its affairs; or (j) if Tenant
shall fail to pay any installment of Annual Fixed Rent or Additional Rent when
due, Tenant shall cure such default within the grace period provided in clause
(a) (I) above (or with Landlord's approval after the expiration of such grace
period) and Tenant shall, within the next year following the date such initial
defaulted payment was first due, fail more than once to pay any installment of
Annual Fixed Rent or Additional Rent when due, then, and in any of such cases
indicated in clauses (a) through (j) hereof (collectively and individually, a
"Default of Tenant"), Landlord may, in addition to and not in derogation of any
remedies for any preceding breach of covenant, immediately or at any time
thereafter give notice to Tenant terminating this Lease and the term hereof,
which notice shall specify the date of termination, whereupon on the date so
specified, the term of this Lease and all of Tenant's rights and privileges
under this Lease shall expire and terminate but Tenant shall remain liable as
hereinafter provided.
8.2 Remedies. In the event of any termination pursuant to Section 8.1,
Tenant shall pay the Annual Fixed Rent, Additional Rent and other charges
payable hereunder up to the time of such termination. Thereafter, whether or not
the Premises shall have been re-let, Tenant shall be liable to Landlord for, and
shall pay to Landlord the Annual Fixed Rent, Additional Rent and other charges
which would be payable hereunder for the remainder of the term of this Lease had
such termination not occurred, less the net proceeds, if any, of any reletting
of the Premises, after deducting all commercially reasonable expenses in
connection with such reletting, including, without limitation, all repossession
costs, brokerage commissions, attorneys' fees and expenses, advertising costs,
administration expenses, alteration costs, the value of any tenant inducements
(including but without limitation free rent, moving costs, and contributions
toward leasehold improvements) and any other commercially reasonable expenses
incurred in preparation for such reletting. Tenant shall pay such damages to
Landlord monthly on the days on which the Annual Fixed Rent, Additional Rent or
other charges would have been payable hereunder if the term of this Lease had
not been so terminated.
At any time after such termination, in lieu of recovering damages pursuant
to the provisions of the immediately preceding paragraph with respect to any
period after the date of demand therefor, at Landlord's election, Tenant shall
pay to Landlord the amount, if any, by which (A) the Annual Fixed Rent,
Additional Rent and other charges which would be payable hereunder from the date
of such demand to the end of what would be the then unexpired term of this Lease
had such termination not occurred, shall exceed (B) the then fair rental value
of the
-38-
Premises for the same period, reduced to amortize over such period all costs or
expenses which Landlord would incur to obtain such fair market rent.
Nothing contained in this Lease shall, however, limit or prejudice the
right of Landlord to prove for and obtain in proceedings for bankruptcy or
insolvency by reason of the termination of this Lease, an amount equal to the
maximum allowed by any statute or rule of law in effect at the time when, and
governing the proceedings in which, the damages are to be proved, whether or not
the amount be greater than, equal to, or less than the amount of the loss or
damages referred to above.
In case of any Default of Tenant, re-entry, expiration and repossession by
summary proceedings or otherwise, Landlord may (i) relet the Premises or any
part or parts thereof, either in the name of Landlord or otherwise, for a term
or terms which may at Landlord's option be equal to or less than or exceed the
period which would otherwise have constituted the balance of the term of this
Lease and may grant concessions or free rent to the extent that Landlord
considers advisable and necessary to relet the same and (ii) may make such
alterations, repairs and decorations in the Premises as Landlord in its sole
judgment considers advisable and necessary for the purpose of reletting the
Premises; and the making of such alterations, repairs and decorations shall not
operate or be construed to release Tenant from liability hereunder as aforesaid.
Landlord shall in no event be liable in any way whatsoever for failure to relet
the Premises provided Landlord shall comply with its obligations hereinafter
described, or, in the event that the Premises are relet, for failure to collect
the rent under such reletting.
Landlord shall make a good faith effort to relet the Premises following a
termination of the term of this Lease due to a Default of Tenant, but subject to
and in accordance with the following criteria:
(i) Landlord shall have no obligation to solicit or
entertain negotiations with any other prospective
tenants for the Premises until Tenant shall have
surrendered possession of the Premises in the condition
required by Section 6.1.9 hereof;
(ii) Landlord shall have no obligation to offer the Premises
to any prospective tenant so long as other premises in
the Building suitable for that prospective tenant are
currently available, or are reasonably expected to be
available within the next six (6) months;
(iii) Landlord shall have no obligation to enter into a lease
of less than all of the Premises;
(iv) Landlord shall have no obligation to enter into a lease
under terms and conditions that are inconsistent with
Landlord's then current leasing policies for comparable
space in the Building;
(v) Landlord shall have no obligation to enter into a lease
with any proposed tenant that does not have, in
Landlord's reasonable opinion, sufficient financial
resources and operating experience;
-39-
(vi) Landlord shall not be required to expend any amount of
money to alter, remodel, or otherwise make the Premises
or the Building suitable for use by a prospective tenant
unless either (1) Tenant pays any such sum to Landlord
in advance of Landlord's execution of a lease with such
prospective tenant (which payment shall be in addition
to any other damages or amounts to which Landlord may be
entitled to as a result of Tenant's default under this
Lease); or (2) Landlord, in Landlord's sole discretion,
determines that any such expenditure is financially
justified in connection with entering into any lease
with such prospective tenant; and
(vii) Landlord shall have no obligation to enter into a lease
with any prospective tenant whose use would: (1) violate
any restriction, covenant, or requirement contained in
the lease of another tenant of the Building; (2)
adversely affect the reputation of the Building; (3) be
incompatible with the operation of the Building as a
first-class building; or (4) require any alterations to
the Building.
Tenant hereby waives and releases, to the fullest extent legally
permissible, any right to assert in any action by Landlord to enforce the terms
of this Lease, any defense, counterclaim, or right of setoff or recoupment
respecting the mitigation of damages by Landlord, unless and to the extent
Landlord fails to act in accordance with the requirements of this Section 8.2.
To the fullest extent permitted by law, Tenant hereby expressly waives any
and all rights of redemption granted under any present or future laws in the
event of Tenant being evicted or dispossessed; or in the event of Landlord
obtaining possession of the Premises, by reason of the violation by Tenant of
any of the covenants and conditions of this Lease.
8.3 Remedies Cumulative. Except as expressly provided otherwise in
Section 8.2, any and all rights and remedies which Landlord may have under this
Lease, and at law and equity (including without limitation actions at law for
direct, indirect, special and consequential (foreseeable and unforeseeable)
damages), for Tenant's failure to comply with its obligations under this Lease
shall be cumulative and shall not be deemed inconsistent with each other, and
any two or more of all such rights and remedies may be exercised at the same
time insofar as permitted by law.
8.4 Landlord's Right to Cure Defaults. At any time with or without
notice, Landlord shall have the right, but shall not be required, to pay such
sums or do any act which requires the expenditure of monies which may be
reasonably necessary or appropriate by reason of the failure or neglect of
Tenant to comply with any of its obligations under this Lease (irrespective of
whether the same shall have ripened into a Default of Tenant), and in the event
of the exercise of such right by Landlord, Tenant agrees to pay to Landlord
forthwith upon demand, as Additional Rent, all such sums including reasonable
attorneys fees, together with interest thereon at a rate (the "Default Rate")
equal to the lesser of three percent (3%) over the Prime Rate or the maximum
rate allowed by law. "Prime Rate" shall mean the annual floating rate of
interest, determined daily and expressed as a percentage from time to time
announced by Bank of America as its "prime" or "base" rate, so-called, or if at
any time Bank of America ceases to
-40-
announce such a rate, as announced by the largest national or state-chartered
banking institution then having an office in the City of Boston and announcing
such a rate. If at any time neither Bank of America nor the largest national or
state-chartered banking institution having an office in the City of Boston is
announcing such a floating rate, "Prime Rate" shall mean a rate of interest,
determined daily, which is two (2) percentage points above the 14-day moving
average closing trading price of 90-day Treasury Bills.
8.5 Holding Over. Any holding over by Tenant after the expiration or
early termination of the term of this Lease shall be treated as a daily tenancy
at sufferance at a rate equal to one and one-half times the greater of (x) the
fair market rental value for the Premises on a month-to-month basis or (y) the
sum of Annual Fixed Rent plus Additional Rent in effect immediately prior to the
expiration or earlier termination of the term (such sum being (the "Prior
Rent"); provided however if Tenant shall holdover for thirty (30) days or less
and such holding over is the result solely of Tenant having failed to comply
with its obligations under clause (ii) of the last paragraph of Section 6.1.9
(Tenant having complied with all other obligations under Section 6.1.9 by the
expiration or earlier termination of the term) then such holding over shall be
treated as a daily tenancy at sufferance at the Prior Rent until such compliance
occurs. Tenant shall also pay to Landlord all damages, direct and/or
consequential (foreseeable and unforeseeable), sustained by reason of any such
holding over. Otherwise, all of the covenants, agreements and obligations of
Tenant applicable during the term of this Lease shall apply and be performed by
Tenant during such period of holding over as if such period were part of the
term of this Lease.
8.6 Effect of Waivers of Default. Any consent or permission by Landlord
or Tenant to any act or omission by the other shall not be deemed to be consent
or permission by Landlord or Tenant to any other similar or dissimilar act or
omission and any such consent or permission in one instance shall not be deemed
to be consent or permission in any other instance.
8.7 No Waiver, etc. The failure of Landlord or Tenant to seek redress
for violation of, or to insist upon the strict performance of, any covenant or
condition of this Lease shall not be deemed a waiver of such violation nor
prevent a subsequent act, which would have originally constituted a violation,
from having all the force and effect of an original violation. The receipt by
Landlord of rent with knowledge of the breach of any covenant of this Lease
shall not be deemed to have been a waiver of such breach by Landlord, or by
Tenant, unless such waiver be in writing signed by the party to be charged. No
consent or waiver, express or implied, by Landlord or Tenant to or of any breach
of any agreement or duty shall be construed as a waiver or consent to or of any
other breach of the same or any other agreement or duty.
8.8 No Accord and Satisfaction. No acceptance by Landlord of a lesser
sum than the Annual Fixed Rent, Additional Rent or any other charge then due
shall be deemed to be other than on account of the earliest installment of such
rent or charge due, nor shall any endorsement or statement on any check or any
letter accompanying any check or payment as rent or other charge be deemed an
accord and satisfaction, and Landlord may accept such check or payment without
prejudice to Landlord's right to recover the balance of such installment or
pursue any other remedy in this Lease provided.
-41-
ARTICLE 9
Rights of Holders
9.1 Rights of Mortgagees or Ground Lessor. This Lease, and all rights of
Tenant hereunder, are and shall be subject and subordinate to any ground or
master lease, and all renewals, extensions, modifications and replacements
thereof, and to all mortgages, which may now or hereafter affect the Building or
the Property and/or any such lease, whether or not such mortgages shall also
cover other lands and/or buildings and/or leases, to each and every advance made
or hereafter to be made under such mortgages, and to all renewals,
modifications, replacements and extensions of such leases and such mortgages and
all consolidations of such mortgages. This Section shall be self-operative and
no further instrument of subordination shall be required. In confirmation of
such subordination, Tenant shall promptly execute, acknowledge and deliver any
instrument that Landlord, the lessor under any such lease or the holder of any
such mortgage or any of their respective successors in interest may reasonably
request to evidence such subordination. Any lease to which this Lease is subject
and subordinate is herein called "Superior Lease" and the lessor of a Superior
Lease or its successor in interest, at the time referred to, is herein called
"Superior Lessor"; and any mortgage to which this Lease is subject and
subordinate, is herein called "Superior Mortgage" and the holder of a Superior
Mortgage is herein called "Superior Mortgagee".
If any Superior Lessor or Superior Mortgagee or the nominee or designee of
any Superior Lessor or Superior Mortgagee shall succeed to the rights of
Landlord under this Lease, whether through possession or foreclosure action or
delivery of a new lease or deed, or otherwise, then at the request of such party
so succeeding to Landlord's rights (herein called "Successor Landlord") and upon
such Successor Landlord's written agreement to accept Tenant's attornment,
Tenant shall attorn to and recognize such Successor Landlord as Tenant's
landlord under this Lease and shall promptly execute and deliver any instrument
that such Successor Landlord may reasonably request to evidence such attornment.
Upon such attornment, this Lease shall continue in full force and effect as a
direct lease between the Successor Landlord and Tenant upon all of the terms,
conditions and covenants as are set forth in this Lease, except that the
Successor Landlord (unless formerly the landlord under this Lease) shall not be
(a) liable in any way to Tenant for any act or omission, neglect or default on
the part of Landlord under this Lease, (b) responsible for any monies owing by
or on deposit with Landlord to the credit of Tenant provided however if at the
time of such attornment there shall remain any amounts remaining to be paid to
Tenant pursuant to Section 3.6 and such Successor Landlord shall fail to make
payment within thirty (30) days of invoice then such amount unpaid may be offset
against Annual Fixed Rent, (c) subject to any counterclaim or setoff which
theretofore accrued to Tenant against Landlord, (d) bound by any modification of
this Lease subsequent to such Superior Lease or Superior Mortgage, or by any
previous prepayment of Annual Fixed Rent or Additional Rent for more than one
(1) month, which was not approved in writing by the Successor Landlord, (e)
responsible for the performance of any work to be done by Landlord under this
Lease to render the Premises ready for occupancy by the Tenant, or (f) required
to remove any person occupying the Premises or any part thereof, except if such
person claims by, through or under the Successor Landlord. Tenant agrees at any
time and from time to time to execute a suitable instrument in confirmation of
Tenant's agreement to attorn, as aforesaid.
-42-
9.2 Modifications. If any Superior Lessor or Superior Mortgagee shall
require any modification(s) of this Lease, Tenant shall, at Landlord's request,
promptly execute and deliver to Landlord such instruments effecting such
modification(s) as such Superior Lessor or Superior Mortgagee shall require,
provided that such modification(s) do not adversely affect in any material
respect any of Tenant's rights under this Lease. In addition, and
notwithstanding Section 9.1 to the contrary, any Superior Lessor or Superior
Mortgagee may, at its option, subordinate the Superior Lease or Superior
Mortgage of which it is the lessor or holder to this Lease by giving Tenant ten
(10) days prior written notice of such election, whereupon this Lease shall,
irrespective of dates of execution, delivery and recording, be superior to such
Superior Lease or Superior Mortgage and no other documentation shall be
necessary to effect such change.
9.3 Subordination, Non-Disturbance and Attornment. Landlord represents
that as of the Date of this Lease it holds fee title to the Property and that no
Superior Mortgage affects such title. Landlord agrees that, as a condition to
Tenant's obligation to subordinate its interest in this Lease to any Superior
Mortgagee or Superior Lessee, it shall obtain a so-called non-disturbance
agreement from any such Superior Lessor or Superior Mortgagee which agreement
may be in the form customarily used by such Superior Lessor or Superior
Mortgagee if such form is commercially reasonable, or if no such form exists, in
any commercially reasonable form, subject to the conditions and limitations of
Sections 9.1 and 9.2.
ARTICLE 10
Miscellaneous Provisions
10.1 Notices. Except as may be expressly provided herein otherwise, all
notices, requests, demands, consents, approval or other communications to or
upon the respective parties hereto shall be in writing, shall be delivered by
hand or mailed by certified or registered mail, return receipt requested, or by
a nationally recognized courier service that provides a receipt for delivery
such as Federal Express, United Parcel Service or U.S. Postal Service Express
Mail and shall be addressed as follows: If intended for Landlord, to the
Original Address of Landlord set forth in Section 1.1 of this Lease with a copy
to Xxxxxxxx X. Xxxxx, Reit Management & Research LLC, 000 Xxxxxx Xxxxxx, Xxxxxx,
XX 00000 (or to such other address or addresses as may from time to time
hereafter be designated by Landlord by notice to Tenant); and if intended for
Tenant, addressed to Tenant at the Original Address of Tenant set forth in
Section 1.1 of this Lease until the Commencement Date and thereafter to the
Property (or to such other address or addresses as may from time to time
hereafter be designated by Tenant by notice to Landlord) with a copy to Xxxxxx
X. Xxxxx, Faber Daeufer & Xxxxxxxxx PC, 0000 Xxxxxx Xxxxxx, Xxxxx 0000, Xxxxxxx,
XX 00000. Notices shall be effective on the date delivered to (or the first date
such delivery is attempted and refused by) the party to which such notice is
required or permitted to be given or made under this Lease. Notices from
Landlord may be given by Landlord's Agent, if any, or Landlord's attorney.
10.2 Quiet Enjoyment; Landlord's Right to Make Alterations, Etc. Landlord
agrees that upon Tenant's paying the rent and performing and observing the
agreements, conditions and other provisions on its part to be performed and
observed, Tenant shall and may peaceably and quietly have, hold and enjoy the
Premises during the term hereof without any manner of hindrance or molestation
from Landlord or anyone claiming under Landlord, subject, however,
-43-
to the terms of this Lease; provided, however, Landlord reserves the right at
any time and from time to time, with reasonable notice to Tenant, without the
same constituting breach of Landlord's covenant of quiet enjoyment or an actual
or constructive eviction, and without Landlord incurring any liability to Tenant
or otherwise affecting Tenant's obligations under this Lease, to make such
changes, alterations, improvements, repairs or replacements in or to the
interior and exterior of the Building (including the Premises) and the fixtures
and equipment thereof, and in or to the Property, or properties adjacent
thereto, as Landlord reasonably may deem necessary or desirable, and to change
(provided that there be no unreasonable obstruction of the right of access to
the Premises by Tenant and that Landlord use commercially reasonable efforts to
minimize, to the extent practical, any interference with the conduct of business
at the Premises) the arrangement and/or location of entrances or passageways,
doors and doorways, corridors, elevators, or other common areas of the Building
and Property.
Without incurring any liability to Tenant, Landlord may permit access to
the Premises and open the same, whether or not Tenant shall be present, upon any
demand of any receiver, trustee, assignee for the benefit of creditors, sheriff,
marshal or court officer Landlord reasonably believes is entitled to such access
for the purpose of taking possession of, or removing, Tenant's property or for
any other lawful purpose (but this provision and any action by Landlord
hereunder shall not be deemed a recognition by Landlord that the person or
official making such demand has any right or interest in or to this Lease, or in
or to the Premises), or upon demand of any representative of the fire, police,
building, sanitation or other department of the city, state or federal
governments.
10.3 Recording of Lease; Confidentiality of Lease Terms. Landlord
acknowledges that Tenant may record a notice of this Lease with the Registry of
Deeds of Middlesex County in accordance with Mass. Gen. Xxxx Xxx. c. 183 Section
4.
Tenant acknowledges that the terms under which the Landlord has leased the
Premises to Tenant (including, without limitation, the rental rate(s), term and
other financial and business terms), constitute confidential information of
Landlord ("Landlord Confidential Information"). Subject to the preceding
paragraph, Tenant covenants and agrees to keep Landlord Confidential Information
confidential and not to disclose the same to third parties; provided, however,
that Landlord Confidential Information may be disclosed by Tenant to those of
its officers, employees, attorneys, accountants, lenders and financial advisors
(collectively, "Representatives") who need to know such information in
connection with Tenant's use and occupancy of the Premises, enforcement of the
Lease, and for financial reporting, credit related and capital raising
activities. Tenant furthermore agrees to inform Tenant's Representatives of the
confidential nature of Landlord Confidential Information and to use all
reasonable efforts to cause each of Tenant's Representatives to treat Landlord
Confidential Information confidentially and in accordance with the terms of this
paragraph. The obligations in this paragraph shall expire two (2) years after
the end of the term of the Lease.
10.4 Assignment of Rents and Transfer of Title; Limitation of Landlord's
Liability. Tenant agrees that the assignment by Landlord of Landlord's interest
in this Lease, or the rents payable hereunder, whether absolute or conditional
in nature or otherwise, which assignment is made to the holder of a mortgage on
property which includes the Premises, shall never be treated as an assumption by
such holder of any of the obligations of Landlord hereunder unless such
-44-
holder shall, by notice sent to Tenant, specifically otherwise elect and that,
except as aforesaid, such holder shall be treated as having assumed Landlord's
obligations hereunder (subject to the limitations set forth in Section 9.1) only
upon foreclosure of such holder's mortgage and the taking of possession of the
Premises.
The term "Landlord", so far as covenants or obligations to be performed by
Landlord are concerned, shall be limited to mean and include only the owner or
owners at the time in question of Landlord's interest in the Property, and in
the event of any transfer or transfers of such title to said property, Landlord
(and in case of any subsequent transfers or conveyances, the then grantor) shall
be concurrently freed and relieved from and after the date of such transfer or
conveyance, without any further instrument or agreement, of all liability with
respect to the performance of any covenants or obligations on the part of
Landlord contained in this Lease thereafter to be performed, it being intended
hereby that the covenants and obligations contained in this Lease on the part of
Landlord, shall, subject as aforesaid, be binding on Landlord, its successors
and assigns, only during and in respect of their respective period of ownership
of such interest in the Property.
Notwithstanding the foregoing, in no event shall the acquisition of
Landlord's interest in the Property by a purchaser which, simultaneously
therewith, leases Landlord's entire interest in the Property back to Landlord or
the seller thereof be treated as an assumption by operation of law or otherwise,
of Landlord's obligations hereunder. Tenant shall look solely to such
seller-lessee, and its successors from time to time in title, for performance of
Landlord's obligations hereunder. The seller-lessee, and its successors in
title, shall be the Landlord hereunder unless and until such purchaser expressly
assumes in writing the Landlord's obligations hereunder.
Tenant shall not assert nor seek to enforce any claim for breach of this
Lease against any of Landlord's assets other than Landlord's interest in the
Property, and Tenant agrees to look solely to such interest for the satisfaction
of any liability or claim against Landlord under this Lease, it being
specifically agreed that in no event whatsoever shall Landlord be required to
respond in damages from any assets other than its interest in the Property and
the rent therefrom and any insurance proceeds or condemnation award therefor.
Tenant furthermore agrees that no trustee, officer, director, general or limited
partner, member, shareholder, beneficiary, employee or agent of Landlord
(including any person or entity from time to time engaged to supervise and/or
manage the operation of Landlord) shall be held to any liability, jointly or
severally, for any debt, claim, demand, judgment, decree, liability or
obligation of any kind (in tort, contract or otherwise) of, against or with
respect to Landlord or arising out of any action taken or omitted for or on
behalf of Landlord.
10.5 Landlord's Default. Landlord shall not be deemed to be in breach of,
or in default in the performance of, any of its obligations under this Lease
unless it shall fail to perform such obligation(s) and such failure shall
continue for a period of thirty (30) days, or such additional time as is
reasonably required to correct any such breach or default, after written notice
has been given by Tenant to Landlord specifying the nature of Landlord's alleged
breach or default. Tenant shall have no right to terminate this Lease for any
breach or default by Landlord hereunder and no right, for any such breach or
default, to offset or counterclaim against any rent due hereunder. In no event
shall Landlord ever be liable to Tenant for any punitive damages or for any loss
of business or any other indirect, special or consequential damages suffered by
-45-
Tenant from whatever cause. Tenant further agrees that if Landlord shall have
failed to cure any such breach or default within thirty (30) days of such notice
to Landlord (or if such breach or default cannot be cured within said time, then
within such additional time as may be necessary if within said thirty days
Landlord has commenced and is diligently pursuing the remedies necessary to cure
such breach or default), then the holder(s) of any mortgage(s) or the lessor
under any ground lease entitled to notice pursuant to Section 10.6 shall have an
additional thirty (30) days within which to cure such breach or default if such
breach or default cannot be cured within that time, then such additional time as
may be necessary, if within such thirty (30) days any such holder or lessor has
commenced and is diligently pursuing the remedies necessary to cure such breach
or default (including but not limited to commencement of foreclosure
proceedings, if necessary to effect such cure).
10.6 Notice to Mortgagee and Ground Lessor. After receiving notice from
any party that it holds a mortgage which includes the Premises as part of the
mortgaged premises, or that it is the ground lessor under a lease with Landlord,
as ground lessee, which includes the Premises as part of the demised premises,
no notice from Tenant to Landlord shall be effective unless and until a copy of
the same is given to such holder or ground lessor, and the curing of any of
Landlord's defaults by such holder or ground lessor shall be treated as
performance by Landlord.
10.7 Brokerage. Tenant warrants and represents that it has dealt with no
broker in connection with the consummation of this Lease, other than Xxxxxxxx
Xxxxx Xxxxx & Partners ("RBJ&P"), and XxXxxx & Xxxx, Inc. ("M&A"), and in the
event of any brokerage claims or liens, other than by RBJ&P or M&A, against
Landlord or the Property predicated upon or arising out of prior dealings with
Tenant, Tenant agrees to defend the same and indemnify and hold Landlord
harmless against any such claim, and to discharge any such lien. Landlord shall
pay a brokerage fee to RBJ&P pursuant to a separate agreement, and RBJ&P shall
in turn pay M&A a brokerage fee pursuant to an agreement between such two
parties.
10.8 Applicable Law and Construction. This Lease shall be governed by and
construed in accordance with the laws of the state or district in which the
Property is located and if any provisions of this Lease shall to any extent be
invalid, the remainder of this Lease shall not be affected thereby. Tenant
expressly acknowledges and agrees that Landlord has not made and is not making,
and Tenant, in executing and delivering this Lease, is not relying upon, any
warranties, representations, promises or statements, except to the extent that
the same are expressly set forth in this Lease or in any other written agreement
which may be made between the parties concurrently with the execution and
delivery of this Lease and which shall expressly refer to this Lease. All
understandings and agreements heretofore made between the parties are merged in
this Lease and any other such written agreement(s) made concurrently herewith,
which alone fully and completely express the agreement of the parties and which
are entered into after full investigation, neither party relying upon any
statement or representation not embodied in this Lease or any other such written
agreement(s) made concurrently herewith. This Lease may be amended, and the
provisions hereof may be waived or modified, only by instruments in writing
executed by Landlord and Tenant. The titles of the several Articles and Sections
contained herein are for convenience only and shall not be considered in
construing this Lease. The submission of this document for examination and
negotiation does not constitute an offer to lease, or a reservation of, or
option for, the Premises, and Tenant shall have no right to the Premises
hereunder until the execution and delivery hereof by both Landlord and Tenant.
Except
-46-
as herein otherwise provided, the terms hereof shall be binding upon and shall
inure to the benefit of the successors and assigns, respectively, of Landlord
and Tenant and, if Tenant shall be an individual, upon and to his heirs,
executors, administrators, successors and assigns. If two or more persons or
parties are named as Tenant herein, (i) each of such persons or parties shall be
jointly and severally liable for the obligations of the Tenant hereunder, and
Landlord may proceed against any one without first having commenced proceedings
against any other of them and (ii) Landlord may require that all notices,
requests, demands, consents, approvals or other communications delivered by
Tenant under the Lease must be executed by each person or party named as Tenant
herein. Each term and each provision of this Lease to be performed by Tenant
shall be construed to be both an independent covenant and a condition and time
is of the essence with respect to the exercise of any of Tenant's rights under
this Lease. The reference contained to successors and assigns of Tenant is not
intended to constitute a consent to assignment by Tenant. Except as otherwise
set forth in this Lease, any obligations of Tenant (including, without
limitation, rental and other monetary obligations, repair and maintenance
obligations and obligations to indemnify Landlord), shall survive the expiration
or earlier termination of this Lease, and Tenant shall immediately reimburse
Landlord for any expense incurred by Landlord in curing Tenant's failure to
satisfy any such obligation (notwithstanding the fact that such cure might be
effected by Landlord following the expiration or earlier termination of this
Lease).
-47-
WITNESS the execution hereof under seal on the day and year first above
written.
Landlord:
TRUSTEES OF 0 XXXXXXX XXXX REALTY TRUST
By: /s/ XXXX X. XXXXX
-------------------------------------------------
Name: Xxxx X. Xxxxx
Title: Trustee as aforesaid and not individually
Tenant:
PREDIX PHARMACEUTICALS HOLDINGS, INC.
By: /s/ XXXXXXX X. XXXXXXXX
-------------------------------------------------
Its President
By: /s/ CHEN XXXXX
-------------------------------------------------
Its Chief Business Officer
EXHIBIT A
FLOOR PLANS
EXHIBIT A-1
SITE PLAN
EXHIBIT B
RULES AND REGULATIONS
1. The sidewalks, entrances, passages, corridors, vestibules, halls,
elevators or stairways in or about the Building shall not be obstructed by
Tenant.
2. Tenant shall not place objects against glass partitions, doors or
windows which would be unsightly from the Building corridor or from the exterior
of the Building. No sign, advertisement, notice or other lettering shall be
exhibited, inscribed, painted or fixed by Tenant on any window or part of the
outside or inside of the Buildings without prior consent of Landlord.
3. Tenant shall not place a load upon any floor of the Building exceeding
the lesser of the floor load which such floor was designed to carry or that
allowed by law.
4. Tenant shall not waste electricity or water in the Building and shall
cooperate fully with Landlord to assure the most effective operation of the
Building HVAC system. All regulating and adjusting of HVAC equipment shall be
done by the Landlord's agents or employees.
5. No additional or different locks or bolts shall be affixed on doors by
Tenant. Tenant shall return all keys to Landlord upon termination of Tenant's
lease. Tenant shall not allow peddlers, solicitors or beggars in the Building
and shall report such persons to the Landlord's agent.
6. No bicycles, vehicles or animals of any kind shall be brought into or
kept in or about the Premises. No space in the Building shall be used for
manufacturing or for the sale of merchandise of any kind at auction or for
storage thereof preliminary to such sale.
7. Tenant shall not engage or pay any employees of the Building without
approval from the Landlord. Tenant shall not employ any persons other than the
janitor or employees of Landlord for the purpose of cleaning Premises without
the prior written consent of Landlord.
8. All removals from the Building or the carrying in or out of the
Building or the Premises of any freight, furniture or bulky matter of any
description must take place at such time and in such manner as Landlord may
determine from time to time. Landlord reserves the right to inspect all freight
to be brought into the Building and to exclude from the Building all freight
which violates any of the rules and regulations or provisions of Tenant's lease.
9. Normal Building Operating Hours are 7:00 a.m. to 7:00 p.m. Mondays
through Fridays and 9:00 a.m. to 1:00 p.m. on Saturdays excluding New Years Day,
Xxxxxx Xxxxxx Xxxx'x Birthday, President's Day, Memorial Day, Independence Day,
Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day (and the
applicable weekday when any such day occurs on a weekend day) and all other
federal, state, county or municipal holidays and all Sundays, except that
Landlord reserves the option (at its sole election) to expand or alter Normal
Building Operating Hours. Any day (other than a Saturday) on which Normal
Building Operating Hours shall occur shall be a "Business Day". Outside of
Normal Building Operating
Hours, Landlord reserves the right to exclude from the Building all persons
connected with or calling upon Tenant who do not present a pass to the Building
signed by Tenant. Landlord will furnish passes to persons designated by Tenant
and Tenant shall be responsible to Landlord for all acts of such persons.
10. Tenant shall cooperate with Landlord in minimizing loss and risk
thereof from fire and associated perils.
11. Tenant shall, at Tenant's expense, provide artificial light and
electric current for the Landlord and/or its contractors, agents and employees
during the making of repairs, alterations, additions or improvements in or to
the demised premises.
12. The water and wash closets and other plumbing fixtures shall not be
used for any purposes other than those for which they were designed and
constructed and no sweepings, rubbish, rags, acid or like substance shall be
deposited therein. All damages resulting from any misuse of the fixtures shall
be borne by Tenant.
13. Tenant may request HVAC service outside of Normal Building Operating
Hours by submitting a request in writing to the Building Manager's office by
noon of the preceding workday.
14. Landlord reserves the right to establish, modify and enforce parking
rules and regulations.
15. All refuse from the Premises shall be disposed of in accordance with
the requirements established therefor by Landlord and no dumpster shall be
overloaded by Tenant.
16. Landlord reserves the right at any time to rescind, alter or waive any
rule or regulation at any time prescribed for the Building and to impose
reasonable additional rules and regulations when in its judgment Landlord deems
it necessary, desirable or proper for its best interest and for the best
interest of tenants and other occupants and invitees thereof. No alteration or
waiver of any rule or regulation in favor of one tenant shall operate as an
alteration or waiver in favor of any other tenant. Landlord shall not be
responsible to any tenant for the non-observance or violation by any other
tenant however resulting of any rules or regulations at any time prescribed for
the Building.
-2-
EXHIBIT C
ALTERATIONS REQUIREMENTS
A. General
1. All alterations, installations or improvements ("Alterations") to be
made by Tenant in, to or about the Premises, including any Alterations to be
made prior to Tenant's occupancy of the Premises for the Permitted Use, shall be
made in accordance with the requirements of this Exhibit and with any additional
requirements stated in the Lease. For clarity, the requirements of this Exhibit
do not apply to Landlord's Work.
2. All submissions, inquiries approvals and other matters shall be
processed through Landlord's Building manager or regional property manager.
3. Additional and differing provisions in the Lease, if any, will be
applicable and will take precedence over the terms of this Exhibit.
B. Plans
1. Before commencing construction of any Alterations, Tenant shall
submit for Landlord's written approval either a description of the Alterations
or drawings and specifications for the Alterations, as follows:
(i) Tenant shall submit drawings and written specifications
(collectively, "Plans") for all of Tenant's Alterations, including
mechanical, electrical and cabling, plumbing and architectural
drawings. Drawings are to be complete, with full details and finish
schedules, and shall be stamped by an architect licensed in the
Commonwealth of Massachusetts certifying compliance with building
codes.
(ii) Tenant may submit a complete description of Tenant's Alterations
(including sketches or diagrams as necessary) in lieu of submitting
Plans if the proposed Alterations meet all of the following
criteria: (1) they are cosmetic in nature (e.g. painting,
wallpapering, installation of floor coverings, etc.), (2) they do
not require a building permit, (3) they do not require work to be
performed inside walls or above the ceiling of the Premises, and (4)
they will not affect the structure or the mechanical, plumbing,
HVAC, electrical or life safety systems of the Building
(collectively, the "Building Systems"). Notwithstanding that
Tenant's proposed Alterations satisfy all of the preceding criteria,
upon review of Tenant's submission, Landlord shall have the right to
require Tenant to submit Plans for all or any portion of the
proposed Alterations.
2. Landlord shall review the description or Plans submitted by Tenant
("Tenant's Design Submission") and notify Tenant of approval or disapproval. If
in the exercise of its reasonable discretion Landlord disapproves Tenant's
Design Submission, Landlord shall specify the reasons for its disapproval and
Tenant shall revise Tenant's Design Submission to meet Landlord's
objections, and shall resubmit the same to Landlord as so revised until Tenant's
Design Submission is approved by Landlord. No approval by Landlord of Tenant's
Design Submission shall constitute a waiver of any of the requirements of this
Exhibit or the Lease. Tenant shall not make any changes to Tenant's Design
Submission after approval by Landlord, including changes required to obtain
governmental permits, without obtaining Landlord's written approval in each
instance.
3. All mechanical, electrical, structural and floor loading
requirements shall be subject to approval of Landlord's engineers. Landlord also
reserves the right to require Tenant to submit copies of shop drawings for
Landlord's review and approval, which may not be withheld, conditioned or
delayed unreasonably.
4. Before commencing construction of any Alterations, Tenant shall
provide Landlord with two (2) complete copies of Tenant's Design Submission in
final form as approved by Landlord.
C. Selection of Contractors and Subcontractors
Before commencing construction of any Alterations, Tenant shall submit to
Landlord the names of Tenant's general contractor (the "General Contractor") and
subcontractors for Landlord's approval. If Landlord shall reject the General
Contractor or any subcontractor, Landlord shall advise Tenant of the reasons(s)
in writing and Tenant shall submit another selection to Landlord for Landlord's
approval.
D. Insurance
Before commencing construction of any Alterations, Tenant will deliver to
Landlord:
(i) Four (4) executed copies of the Insurance Requirements agreement in
the form set forth in Exhibit D from the general contractor and, if
requested by Landlord, from the subcontractors (Landlord will return
two fully executed copies to Tenant), and
(ii) insurance certificates for the General Contractor and subcontractors
as required by Exhibit D, which shall include evidence of coverage
for the indemnity provided by the General Contractor or
subcontractor executing such agreement.
E. Building Permit and Other Legal Requirements
1. Before commencing construction of any Alterations, Tenant shall
furnish Landlord with a valid permit for the construction of the Alterations
from the building department or other agency having jurisdiction in the
municipality in which the Building is located (unless the Alterations are of a
cosmetic nature not requiring a building permit). Tenant shall keep the original
building permit posted on the Premises during the construction of the
Alterations.
2. Tenant Design Submission, the Alterations, and the construction of
the Alterations shall each be in strict compliance with (i) all applicable laws,
codes, rules and regulations, including, without limitation, the Americans with
Disabilities Act, state and local health department requirements, and
occupational health and safety laws and regulations (and no
-2-
approval of Tenant's Design Submission shall relieve Tenant of this obligation
or invest Landlord with any responsibility for ensuring such compliance), and
(ii) all building permits, consents, licenses, variances, and approvals issued
in connection with the Alterations. Tenant shall ensure that the General
Contractor and all subcontractors have the requisite licenses to perform their
work. Tenant shall procure all permits, governmental approvals, licenses,
variances and consents required for the Alterations and shall provide Landlord
with a complete copy thereof promptly upon receipt of same by Tenant.
F. Materials and Workmanship
1. All materials, equipment and installations must meet Landlord's minimum
standards for the Building, as may be designated reasonably by Landlord from
time to time, and all materials shall be new, commercial grade and of
first-class quality. Any deviation from these requirements will be permitted
only if clearly indicated or specified on Tenant's Design Submission and
approved by Landlord.
2. Alterations shall be constructed in a professional, first-class and
workmanlike manner, in accordance with Tenant's Design Submission.
3. The General Contractor shall guaranty all materials and workmanship
against defects for a period of not less than one (1) year from installation.
Notwithstanding any limitations contained in such guaranty or in any contract,
purchase order or other agreement, during the entire term of the Lease, Tenant
shall promptly repair or replace, at Tenant's cost, any defective aspect of the
Alterations except for insubstantial defects that do not adversely effect the
Building or the appearance or rental value of the Premises, as determined by
Landlord in its reasonable discretion.
4. Alterations must be compatible with the existing Building Systems. In
the event any Alterations shall interfere with the proper functioning of any
Building System, Tenant, at Tenant's sole cost and expense, shall promptly cause
such repairs, replacements or adjustments to be made to the Alterations as are
necessary to eliminate any such interference.
G. Prosecution of the Work
1. Landlord may require that all demolition and other categories of work
that may inconvenience other tenants or disturb Building operations be scheduled
and performed in a time and manner least disruptive to other tenants, and Tenant
shall provide the Building manager with at least two Business Days' notice prior
to proceeding with any such work.
2. Unless Landlord directs otherwise, Tenant's contractors shall have
access to the Building during the Normal Building Operating Hours only. If
Tenant's contractors desire access to the Building at any other time, Landlord
shall use reasonable efforts to provide such access, provided, however, that
Tenant shall pay Landlord any additional cost incurred by Landlord to provide
such access, including, without limitation, additional costs for utilities,
personnel, and security.
3. Prior arrangements for elevator use shall be made with the Building
manager by Tenant or the General Contractor. Elevator cabs shall be properly
padded and no material or
-3-
equipment shall be carried under or on top of elevators. If an operating
engineer is required by any union rules, such engineer shall be paid for by
Tenant.
4. Under no circumstances will any material related to Tenant's
Alterations be allowed access through the Building's front entrance without
advance written approval of the Building manager.
5. If shutdown of risers and mains for electrical, HVAC, sprinkler or
plumbing work is required, such work shall be supervised by Landlord's
representative at Tenant's expense. No work will be performed in Building
mechanical equipment rooms except under Landlord's supervision.
6. Alterations shall be performed under the supervision of a
superintendent or xxxxxxx of the General Contractor at all times.
7. All areas adjacent to the construction area shall be sealed with
plastic so as to not be affected by dust and debris. All floors shall be
protected from the construction process.
8. The General Contractor or HVAC subcontractor shall block off supply
and return grilles, diffusers and ducts to keep dust from entering into the
Building HVAC system and thoroughly clean all HVAC units in the work area at the
completion of the Alterations.
9. Construction debris shall be removed from the construction area
daily and the construction area shall be kept neat and reasonably clean at all
times. All construction debris is to be discarded in waste containment provided
by the General Contractor only. No material or debris shall be stored outside
the Premises or Building without the prior written approval of the Landlord's
representative.
10. Landlord shall have the right to instruct the General Contractor to
deliver to Landlord, at Tenant's expense, any items to be removed from the
Premises during the construction of the Alterations.
11. Tenant, either directly or through the General Contractor, will
immediately notify Landlord, in writing, of any damage to the Building caused by
the General Contractor or any subcontractors. Such damage shall be repaired
within 72 hours unless otherwise directed by the Landlord in writing. Any damage
that is not repaired may be repaired by Landlord at Tenant's expense.
12. Construction personnel shall use the restrooms located within the
Premises only. If there are no restrooms within the Premises, then construction
personnel shall use only those Building restrooms located on the floor where the
work is being performed.
13. All wiring and cabling installed by Tenant shall be tagged with
Tenant's name and its specific use and purpose.
14. The General Contractor and all subcontractors shall cause their
employees to adhere to all applicable Rules and Regulations of the Building.
-4-
15. Landlord shall have the right to supervise and inspect the
Alterations as the work progresses and to require Tenant to remove or correct
any aspect of the Alterations that does not conform to Tenant's Design
Submission approved by Landlord.
H. Documents to Be Furnished to Landlord Upon Completion of Tenant's Work
1. Within fifteen (15) days after construction of the Alterations has
been completed, except for so-called punch list items, Tenant shall furnish
Landlord with the following documents:
(i) record "as built" drawings in paper and electronic (CADD) format
showing all of the Alterations as actually constructed for all
portions of the Alterations for which drawings were submitted;
(ii) if Plans for the Alterations were prepared by an architect or
engineer, a written certification from the architect confirming that
the Alterations were completed in material accordance with the Plans
and all applicable laws, codes, ordinances, and regulations;
(iii) full and final lien waivers and releases executed by the General
Contractor and all subcontractors and suppliers;
(iv) if the Alterations include any HVAC work, a properly executed air
balancing report signed by a professional engineer showing that the
HVAC system is properly balanced for the season;
(v) copies of all warranties and guarantees received from the General
Contractor, subcontractors and materials suppliers or manufacturers;
(vi) copies of all maintenance manuals, instructions and similar
information pertaining to the operation and maintenance of equipment
and fixtures installed in the Premises as part of the Alterations;
and
(vii) a copy of the final, permanent certificate of occupancy or amended
certificate of occupancy for the Premises.
-5-
EXHIBIT D
CONTRACTOR'S INSURANCE REQUIREMENTS
Building:
Tenant:
Premises:
The undersigned contractor or subcontractor ("Contractor") has been hired
by the tenant or occupant (hereinafter called "Tenant") of the Building named
above or by Tenant's contractor to perform certain work ("Work") for Tenant in
the Premises identified above. Contractor and Tenant have requested the
undersigned landlord ("Landlord") to grant Contractor access to the Building and
its facilities in connection with the performance of the Work and Landlord
agrees to grant such access to Contractor upon and subject to the following
terms and conditions:
1. Contractor agrees to indemnify and save harmless the Landlord, and
if Landlord is a general or limited partnership each of the partners thereof,
and if Landlord is a nominee trust the trustee(s) and all beneficiaries thereof,
and all of their respective officers, employees and agents, from and against any
claims, demands, suits, liabilities, losses and expenses, including reasonable
attorneys' fees, arising out of or in connection with the Work (and/or imposed
by law upon any or all of them) because of personal injuries, including death,
at any time resulting therefrom and loss of or damage to property, including
consequential damages, whether such injuries to person or property are claimed
to be due to negligence of the Contractor, Tenant, Landlord or any other party
entitled to be indemnified as aforesaid except to the extent specifically
prohibited by law (and any such prohibition shall not void this agreement but
shall be applied only to the minimum extent required by law).
2. Contractor shall provide and maintain at its own expense, until
completion of the Work, the following insurance:
(a) Workmen's Compensation and Employers Liability Insurance covering
each and every xxxxxxx employed in, about or upon the Work, as provided for in
each and every statute applicable to Workmen's Compensation and Employers'
Liability Insurance.
(b) Commercial General Liability Insurance including coverages for
Protective and Contractual Liability (to specifically include coverage for the
indemnification clause of this agreement) for not less than the following
limits:
Bodily Injury: $5,000,000 per person
$5,000,000 per occurrence
Property Damage: $5,000,000 per occurrence
$5,000,000 aggregate
(c) Commercial Automobile Liability Insurance (covering all owned,
non-owned and/or hired motor vehicles to be used in connection with the Work)
for not less than the following limits:
-2-
Bodily Injury: $5,000,000 per person
$5,000,000 per occurrence
Property Damage: $5,000,000 per occurrence.
Contractor shall furnish a certificate from its insurance carrier or
carriers to the Building office before commencing the Work, showing that it has
complied with the above requirements regarding insurance and providing that the
insurer will give Landlord ten (10) days' prior written notice of the
cancellation of any of the foregoing policies.
The insurance provided in (b) and (c) above shall name Landlord as an
additional insured.
3. Contractor shall require all of its subcontractors engaged in the
Work to provide the following insurance:
(a) Commercial General Liability Insurance including Protective and
Contractual Liability coverages with limits of liability at least equal to the
limits stated in paragraph 2(b).
(b) Commercial Automobile Liability Insurance (covering all owned,
non-owned and/or hired motor vehicles to be used in connection with the Work)
with limits of liability at least equal to the limits stated in paragraph 2(c).
Upon the request of Landlord, Contractor shall require all of its
subcontractors engaged in the Work to execute an Insurance Requirements
agreement in the same form as this Agreement.
Agreed to and executed this ____ day of________, 20___.
Contractor: Landlord:
By.________________ By:__________________
By.________________ By:__________________
-2-
EXHIBIT E
CLERK'S CERTIFICATE
I, _______________, the duly elected and acting [Secretary/Clerk] of
__________, a ______ corporation (the "Corporation"), hereby certify that:
(A) at a meeting of the board of directors of the Corporation held on
_____ in accordance with law and the Bylaws of the Corporation the following
resolutions were duly adopted:
VOTED: a. To approve a lease of approximately __________ square feet
of space for terms of ______ years with respect to ___________________in
the building commonly known as _____________in ___________, which lease
grants the Corporation an option to extend the term for ______________
terms of ____years each, substantially in the form of the draft presented
at this meeting, a copy of which shall be placed on file in the office of
the [Secretary/Clerk] and be incorporated by reference in this vote;
b. To authorize ____________ and ___________, or any one of them
(each hereinafter referred to as a "Signatory"), to execute and deliver in
the name and on behalf of the Corporation the above-described lease and to
execute and deliver all other documents, agreements and instruments,
including, without limitation, notices of lease, and to take all other
actions with respect to the foregoing which any Signatory, in such
Signatory's discretion, shall determine to be necessary or appropriate to
effect or secure the transactions contemplated herein, the execution and
delivery of any of the foregoing or the taking of any such action to be
conclusive evidence of such Signatory's determination and of the
Signatory's authority so to do granted by this vote;
(B) as of this date the following individuals are duly elected and
qualified officers of the Corporation holding at this date, the offices
specified next to their names and the signature next to each such name is such
individual's true signature.
NAME OFFICE SIGNATURE
-------------- ----------------- -----------------
-------------- ----------------- -----------------
(C) The form of lease attached to this Certificate is the form referred
to in the foregoing vote.
(D) The resolutions set forth above are unmodified and continue to be in
full force and effect and the Corporation has adopted no other resolutions in
respect of the subject matter thereof.
In witness whereof, I have hereunto set my hand and affixed the seal of
the Corporation this ____ day of __________, 20_.
___________________________
[Secretary/Clerk]
EXHIBIT 1
SHELL/CORE & TENANT RESPONSIBILITY MATRIX ______________________________________
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
----------- ---------------------------- ---------- ---------- ------
Sitework: Additional gas service to X
building for upgraded base
building systems.
Additional gas service to X
building for new tenant
building systems.
Lab waste system connection X
and monitoring manhole.
Code Building renovations in X X
Compliance: accordance with
requirements of
Massachusetts State
Building Code, 6th edition.
Structure: Floor loads; 100 psf first X
floor; 100 psf second floor.
Live load increases for X
special tenant loads at
floors and roof.
Dunnage at roof for X
upgraded base building
equipment.
Dunnage at roof for tenant X
equipment.
Miscellaneous metal items X
and concrete pads related
to tenant fitout.
Exterior: Existing exterior brick and X
glass wall system.
Penthouse and/or screening X
for tenant equipment, to be
bulk in accordance with
base building design and
town requirements
Roofing: Existing roofing system, X
single-ply.
Repair or replacement of X
existing roofing if
required by base building
MEP upgrades.
Roofing penetrations for X
tenant equipment or
systems, to be made in
accordance with roofing
manufacturer's details and
warranty requirements.
Walkway pads to base X X
building and upgrade
mechanical equipment.
Walkway pads to tenant X
mechanical equipment.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
---------- --------------------------------- ---------- ---------- ------
Common Existing finished first floor X
Areas: building lobby and egress
corridors, including stone/tile
flooring, drywall and suspended
ceilings and appropriate accent
lighting.
Existing toilet rooms. X
Existing janitor, electrical and X
telephone closets.
Finished exit stairways with X
painted walls.
Existing finished loading area. X
First floor main X X
mechanical/electrical rooms for
base building and upgrade
equipment.
Existing first floor mechanical X
rooms for tenant lab systems.
Additional first floor tenant X
mechanical rooms.
Existing first floor lab waste X
system room for tenant
neutralization system.
Additional first floor tenant X
rooms for lab waste system(s)
Existing storage space for X
flammable materials, including
spill containment.
Additional storage for tenant X
flammable materials.
Existing doors and frames at X
common areas.
Additional or modified doors, X
frames, and hardware at tenant
areas.
Elevators: Existing passenger/service X
elevator.
Window Existing building standard blinds X
Treatment: on all windows.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
------------ --------------------------- ---------- ---------- ------
Tenant Area: Existing partitions, X
ceilings, flooring,
painting, finishes, doors,
millwork, casework, and all
office, laboratory, and
animal space build-out
within tenant area.
Modifications to partitions X
and tenant build-out.
Shaft enclosures for base X X
building systems.
Shaft enclosures for tenant X
systems.
Modification/relocation of X
existing lab casework.
Equipment: Existing warm/cold rooms, X
autoclaves, glass & cage
washers.
Modification/relocation of X
existing or additional
warm/cold rooms,
autoclaves, glass & cage
washers.
New steam generators. X
Existing laboratory fume X
hoods in current locations.
Relocated or new X
laboratory fume hoods.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
----------- ---------------------------- ---------- ---------- ------
Fire Combination X
Protection: sprinkler/standpipe system
with fire department valves.
Fire service and X
double-check valve assembly.
Alarm check valve and X
stamese connection
Floor Control valve X
assemblies and test drains.
Sprinkler coverage to all X
core areas
Branch distribution. X
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
--------- ----------------------------------- ---------- ---------- ------
Electric: Pad-mounted utility-supplied X
480/277V transformer.
480/277V, 3 phase, 4 wire main X
switchboard, 2500 amp, metered,
for base building and tenant
systems.
Tenant meters at floors. X
Standby generator for tenant X
systems and equipment, including
fuel storage and transfer system,
and acoustic enclosure.
Electric closets, if required, for X
tenant areas.
Power distribution for tenant areas X
Fire Alarm system and risers. X
Fire Alarm devices in tenant X
spaces.
Lighting in common and base X
building areas.
Lighting in tenant areas. X
Lighting protection system, if X
required.
Telephone/data system, including X
service, risers, wiring, closets,
and distribution.
Security System including access X
control, CCTV, etc.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
--------- ---------------------------- ---------- ---------- ------
Secondary file sprinkler X
coverage to lab areas.
Flow switches, tamper X
switches, pressure switches.
Modification of sprinkler X
piping and hand layout to
suit tenant build-out and
hazard index.
Plumbing: Gas service and X X
distribution for base
building and upgrade
systems.
Gas service and X
distribution for tenant
systems.
Extension of existing X
sanitary waste system into
new lab areas areas.
Existing lab waste X
neutralization system.
Additional lab X
neutralization system(s)
for additional tenants.
Existing lab waste and vent X
system.
Modifications to laboratory X
waste and vent system from
lab sinks and equipment.
Domestic water from meter X
to all core fixtures and
wet columns and penthouse
requiring cold water.
Backflow preventers at
entrance.
Electric Domestic point of X
use water heaters and hot
water supply piping to all
core fixtures.
Protected cold water system X
and risers.
Protected cold water X
distribution and check
valves from risers to all
lab sinks and equipment in
tenant areas.
Backflow devices for X
protected water system.
Protected water heaters. X
Protected hot water X
distribution and
circulation to all sinks
and equipment requiring hot
water.
Tempered water systems to X
eye wash units and
emergency showers in
laboratory areas and
electric water heater.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
-------- ---------------------------------- ---------- ---------- ------
HVAC: Air handler capacity, 1.25 cfm/sf X
for base building and tenant
office areas.
Air handler capacity, 2.0 cfm/sf X
for tenant lab areas, based on 70%
lab/30% office.
Exhaust capacity for common areas X
& toilets, per code
Exhaust capacity for lab X
requirements, 2.0 cfm/sf of tenant
lab area
100% outdoor air handler(s) for X
animal facility, if required.
Supply, return, & exhaust duct X
risers for base building systems
Supply & exhaust duct risers for X
base building upgrade systems
Supply & exhaust duct risers for X
additional tenant systems
Laboratory and fume hood exhaust X
risers.
Supply, return, and exhaust X
system, including ductwork,
control boxes, grilles, registers
& diffusers in tenant areas.
Air cooled chillers, 480 tons for X
base building systems.
Hot water boilers 270 BHp for base X
building systems.
Additional/Increased hot water X
boiler capacity for base building
air handling capacity upgrade
Additional hot water or steam X
boilers for tenant systems.
Hot water risers and distribution X X
for base building and upgrade
systems.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
-------- -------------------------- ---------- ---------- ------
Laboratory vacuum system X
distribution piping to
outlets.
Compressed air system and X
distribution piping to
outlets.
Special gas cylinders and X
piping (point-of-use).
RO/DI grade water system X
and distribution piping to
outlets.
Shell/Core Shell/Core
Elements Description Existing Upgrade Tenant
-------- --------------------------------- ---------- ---------- ------
Chilled water distribution for X
base building air handling units.
Air cooled chillers and chilled X
water distribution system for
tenant use.
Hot water distribution system X
within tenant areas.
Automatic temperature control X X
system for base building and
upgrade systems.
Automatic temperature control X
system for tenant areas and
systems.
EXHIBIT 2
Exterior Work
1. Install a landscaped barrier to reduce the view of the loading dock area.
2. Perform improvements to the Property's landscaping.
3. Create a new building entrance, Building lobby and stairwell.
FIRST AMENDMENT TO LEASE
This is a First Amendment to Lease (this "Amendment") dated as of August
31, 2006 by and between Trustees of 0 Xxxxxxx Xxxx Realty Trust under
Declaration of Trust dated January 30, 1998 and filed with Middlesex County
Registry District of the Land Court as Document No. 1054066 ("Landlord") and
EPIX Delaware, Inc., a Delaware corporation ("Tenant").
WHEREAS, Landlord and Predix Pharmaceutical Holdings, Inc. ("Predix")
entered into a lease (the "Lease") dated January 25, 2005 with respect to
certain premises in the building located at 0 Xxxxxxx Xxxx, Xxxxxxxxx,
Xxxxxxxxxxxxx;
WHEREAS, pursuant to that certain Agreement and Plan of Merger dated April
3, 2006 (the "Merger Agreement") among Predix, EPIX Pharmaceuticals, Inc.
("EPIX") and Tenant, a wholly owned subsidiary of EPIX, Predix merged with and
into Tenant and all the property, rights, privileges, powers and franchises of
Predix vested in Tenant as the combined company, and all debts, liabilities,
obligations and duties of Predix became the debts, liabilities, obligations and
duties of Tenant as the combined company, and in furtherance of the foregoing,
Tenant has succeeded to the interest of Predix as tenant under the Lease; and
WHEREAS, Tenant desires to expand the premises demised by the Lease and
extend the term of the Lease.
NOW, THEREFORE, in consideration of the foregoing and for other
consideration the receipt and sufficiency of which are hereby mutually
acknowledged, Landlord and Tenant agree to amend the Lease as follows:
1. Capitalized terms used herein without definition shall have the
meanings ascribed to them by the Lease.
2. Section 1.1 of the Lease is amended by amending the following defined
terms contained therein to have the meanings hereinafter provided:
Premises: From the Commencement Date through the day preceding the
Expansion Date, the area (the "Initial Space") shown on Exhibit A. From and
after the Expansion Date, the Premises shall be all of the rentable areas of the
Building.
Premises Rentable Area: 29,131 square feet through the day preceding the
Expansion Date, and 57,303 square feet thereafter.
Original Term: Commencing on October 15, 2005 (the "Commencement Date")
and expiring on the date which is the day preceding the eighth anniversary of
the Expansion Date.
Annual Fixed Rent: Annual Fixed Rent shall be the sum of the amounts set
forth below for the Initial Space and the Expansion Space and shall be in
addition to the amounts (which have been paid by Tenant) which were due pursuant
to Section 3.7 of the Lease for the period from June 1, 2005 through October 14,
2005.
-2-
Initial Space
December 15, 2005 - December 14, 2006 $ 474,543.99
December 15, 2006 - December 14, 2007 $ 569,511.05
December 15, 2007 - December 14, 2010 $ 728,275.00(per annum)
December 15, 2010 - December 14, 2012 $ 801,102.50(per annum)
December 15, 2012 - End of Year 6 $ 946,757.50(per annum)
Year 7 $ 975,888.50
Year 8 $ 1,005,019.50
Expansion Space
Year 1 $ 577,526.00(per annum)
Year 2 $ 802,902.00
Year 3 $ 831,074.00
Year 4 $ 859,246.00
Year 5 $ 887,418.00
Year 6 $ 915,590.00
Year 7 $ 943,762.00
Year 8 $ 971,934.00
The first "Year" shall be the period beginning on the date (the "Expansion
Rent Start Date") which is thirty (30) days following the Expansion Date and
ending on the day preceding the first (1st) anniversary of the Expansion Date,
with each succeeding Year being the twelve (12) month period following the
preceding Year.
The parties agree that upon the determination of the Expansion Date and
Expansion Rent Start Date, the parties will upon request of either execute a
schedule of the Annual Fixed Rent for the Initial Space and the Expansion Space
that specifies the actual dates for which the applicable Annual Fixed Rent will
be due, which, upon execution, shall be attached as Schedule 1 to this
Amendment.
If the Expansion Rent Start Date occurs on a day other than the first day
of a calendar month, then Annual Fixed Rent for the Expansion Space shall be
prorated for the balance of that month based upon the actual number of days from
the Expansion Rent Start Date through the last day of said calendar month.
Annual Fixed Rent relating to the Expansion Space for any month
-3-
during which Annual Fixed Rent shall change after the first day of such month as
a result of the commencement of a new Year during such month (and Annual Fixed
Rent for each December through Year 6 pursuant to the schedule above for the
Initial Space) shall be the sum of similarly pro-rated amounts for the period in
such month prior to such change and the period in such month from and after such
change.
Tenant's Percentage: 50% until the day preceding the Expansion Date, and
100% thereafter.
Security Deposit: $450,000 until August 28, 2006, $725,000 thereafter,
subject to reduction as provided in Section 4.7.
3. Section 2.4 of the Lease shall be deleted. Landlord and Tenant agree
that the Premises Rentable Area identified in Section 1.1 (as amended hereby) is
recited for administrative purposes only and that, although the Annual Fixed
Rent and other calculations have been determined by reference to such square
footage (regardless of the possibility that the actual measurement of the
rentable area of the Premises may be more or less than the number identified,
irrespective of measurement used), Annual Fixed Rent and such other results and
defined terms shall not be changed.
4. All of the rights and obligations of Landlord and Tenant pursuant to
Article 3 of the Lease have been satisfied. The parties have no other
obligations thereunder, except that Section 3.5 of the Lease shall apply to
Tenant's Work, and subject to the credit to Tenant for the remaining Landlord's
Contribution, as further provided in the fourth paragraph of Section 11 of this
Amendment.
5. Tenant shall continue to have its statutory right to file for Tax
abatements pursuant to Mass. Gen. Xxxx Xxx. c. 59 Section 59.
6. The fourth sentence of Section 4.7 of the Lease shall be amended by
replacing the language preceding the semi-colon with the following:
"The Security Deposit shall be reduced to $625,000 on December 15,
2007, to $525,000 on December 15, 2008, to $425,000 on December 15, 2009,
to $325,000 on December 15, 2010 and to $225,000 on December 15, 2011".
Language following the semi-colon shall remain in place. The Security
Deposit may be increased as required hereby by means of an amended Letter of
Credit or by a replacement Letter of Credit.
7. From and after the Expansion Date, Tenant shall be entitled to use all
parking spaces at the Property and to designate as many reserved spaces as it
elects, notwithstanding Section 5.5(a) of the Lease to the contrary; provided
that Landlord shall be entitled to use such spaces as shall be reasonably
required to enable Landlord to comply with its obligations under the Lease and
to exercise its rights thereunder.
8. The following clause found in Section 6.1.9 of the Lease shall be
deleted:
-4-
["any Leasehold Improvement Work except as may be determined by
Landlord at the time of approval of Tenant's Plans or"].
9. (a) The second paragraph of Section 6.2.7 of the Lease shall be amended
by replacing the phrase "seventy percent (70%) of the Premises" with the
following phrase:
"one (1) floor of the Building."
(b) Tenant shall, subject to the provisions of Section 6.2.7, be
entitled to install a second Tenant's Sign on the exterior of the Building
and an additional sign in the lobby of the Building. All exterior signs
shall be a "Tenant's Sign" for purposes of Section 6.2.7. In addition,
from and after the date of this Amendment, the right to install a
building-mounted sign shall be exclusive to Tenant.
10. Section 7.4 of the Lease shall be deleted.
11. Tenant shall prepare plans and specifications ("New Plans") for any
alterations and improvements it desires to have made to the Premises and shall
submit such New Plans to Landlord for its approval pursuant to Section 6.2.5 of
the Lease. All mechanical, electrical and plumbing plans and specifications
shall be prepared by AHA. Notwithstanding any other provisions set forth in
Section 6.2.5, Richmond Group is hereby approved by Landlord as a contractor
acceptable to Landlord to perform Tenant's Work.
Following commencement of any work specified in the New Plans approved by
Landlord ("Tenant's Work"), Tenant shall, in accordance with Section 6.2.5
hereof, Exhibit C and the New Plans, thereafter diligently and continuously
perform such Tenant's Work until it is substantially complete.
Tenant's Work shall be considered substantially complete and the "New
Completion Date" shall occur on the first day as of which all of the following
requirements have been met: (i) all work shown and described in the New Plans
have been completed, with only punchlist items (i.e., minor and insubstantial
details of decoration or mechanical adjustment) excepted; (ii) Tenant's
architect has issued a certificate of substantial completion on the standard AIA
form, which has been delivered to Landlord; (iii) all electrical, mechanical,
plumbing and HVAC facilities installed by Tenant are functioning properly; and
(iv) all required governmental inspections have been successfully completed and
a final certificate of occupancy has been issued for the Premises.
Provided the Lease is then in full force and effect, Landlord shall
provide Tenant with an improvement allowance (the "New Contribution") equal to
the lesser of (i) the sum of $3,239,780.00 plus $194,000 (the latter amount
being the balance remaining from Landlord's Contribution after payment of the
cost of the Leasehold Improvement Work performed pursuant to Article 3 of the
Lease and Associated Costs pursuant to Section 3.6 hereof), or (ii) the direct,
third-party costs of Tenant's Work. For purposes hereof, the "cost" of Tenant's
Work shall mean (1) fees paid to architectural and engineering professionals to
prepare the New Plans; (2) contractor charges for labor and materials and profit
to perform Tenant's Work; (3) filing fees and other permitting costs pertaining
to Tenant's Work; and (4) a reasonable construction
-5-
management fee payable to any independent construction management firm retained
by Tenant to manage the construction of Tenant's Work.
Notwithstanding the foregoing, Tenant may apply up to $100,000 of the New
Contribution (and reduce the amount of New Contribution available for
application against the cost of Tenant's Work on a dollar-for-dollar basis)
toward the cost to be incurred by Tenant for new office furniture for the
Premises; in which event Landlord shall reimburse Tenant up to such amount
within thirty (30) days of request therefor together with paid invoices, and
provided there shall exist no Default of Tenant and such invoices are delivered
to Landlord by the date (the "Reimbursement Date") which is two (2) years after
the Expansion Date. Tenant shall not be entitled to apply any portion of
Landlord's Contribution (or the New Contribution) toward Annual Fixed Rent.
Tenant may requisition Landlord for payment of the New Contribution
monthly, provided that Landlord may withhold five percent (5%) of the amount due
on each requisition paid prior to the New Completion Date (hereinafter "Progress
Payments").
Each requisition for a Progress Payment shall include (i) a detailed
breakdown of the costs of Tenant's Work, (ii) a copy of each Application for
Payment (on the standard AIA form) from Tenant's contractor for all contractor
charges included in the requisition, (iii) copies of architectural invoices,
(iv) a copy of each Certificate for Payment (substantially on the standard AIA
form) issued by Tenant's architect with respect to each Application for Payment
submitted with the requisition, including, in addition to any certification to
Tenant, the architect's certification to Landlord that all of Tenant's Work to
be paid for by the Progress Payment has been completed in accordance with
Tenant's Plans, (v) executed waivers of mechanic's or material supplier's liens
(in such form as Landlord shall reasonably require) waiving, releasing and
relinquishing all liens, claims and rights to lien under applicable laws on
account of any labor, materials and/or equipment furnished by such party through
the date of the requisition (provided that any such waiver may be conditioned
upon receipt of the amount requested for such party in the requisition), and
(vi) a certification of Tenant that Tenant has made full payment for all
Tenant's Work covered by the prior Progress Payments. Landlord shall make each
Progress Payment (in an amount not to exceed the lesser of (x) the costs of
Tenant's Work as evidenced by the documentation submitted with the applicable
requisition, or (y) the balance of the New Contribution then remaining, less
amounts retained by Landlord as hereinabove provided) to Tenant within thirty
(30) days after Landlord's receipt of a Progress Payment requisition with all
required supporting documentation unless within such period, Landlord notifies
Tenant of its rejection of all or part of such requisition as a result of
Tenant's failure to comply with the requirements hereof, specifying the reasons
therefor, and if Landlord so notifies Tenant, then upon reasonable satisfaction
of such objections, Landlord shall pay any amount withheld within ten (10) days
thereafter.
After the occurrence of the New Completion Date, Tenant may submit a
requisition to Landlord for payment of the balance of the New Contribution (the
"Final Payment"). Such requisition shall include: (i) a final detailed breakdown
of all of the costs of Tenant's Work and (ii) final mechanic's and material
suppliers liens, and (iii) all other documentation required for the Progress
Payment pursuant to the preceding paragraph as to the portion of Tenant's Work
covered by the Final Payment. Landlord shall make the Final Payment within
thirty (30) days
-6-
after Landlord's receipt of a timely requisition for the Final Payment with all
required supporting documentation unless, within such period, Landlord notifies
Tenant of its rejection of all or part of such requisition as a result of
Tenant's failure to comply with the requirements hereof, specifying the reasons
therefor, and, if Landlord so notifies Tenant, then upon reasonable satisfaction
of such objections, Landlord shall pay any amount withheld within ten (10) days
thereafter.
Notwithstanding the foregoing to the contrary, Landlord shall have no
obligation to make any Progress Payment or the Final Payment at any time during
which there shall be a Default of Tenant.
Landlord shall perform the Shell and Core work identified on Exhibit 1 of
the Lease to the area (the "Expansion Space") being added to the Premises
pursuant to this Amendment. In addition, Landlord shall, at its sole cost and
expense, remove all existing interior non-structural improvements in the
Expansion Space including but not limited to interior walls (unless Tenant
timely identifies them to be left in place), carpet, dropped ceilings, lights,
and all mechanical, electrical and plumbing systems and shall level and repair
the floor of the former conference area, all in order to leave the Expansion
Space in "shell" condition. All of the work described in this paragraph is
hereinafter referred to as the "New Landlord Construction".
The "Expansion Date" shall be the earliest to occur of (i) the date on
which the New Landlord Construction shall have been substantially completed,
(ii) March 1, 2007, or (iii) the date on which a temporary certificate of
occupancy for the office portion of the Expansion Space shall have been issued.
If the cost of Tenant's Work shall be less than $3,433,780.00, then any
difference (less amounts applied toward furniture costs, as hereinabove
provided) shall be made available to Tenant for the reimbursement of the cost of
any alterations or improvements which Tenant elects to perform to the Premises
after the New Completion Date in compliance with the terms of the Lease
(including Landlord's approval of plans and specifications therefor), subject to
the following conditions; Reimbursement shall be made by Landlord within thirty
(30) days following receipt by Landlord of invoices for such work from Tenant's
contractor(s) and lien waivers from such contractors and any subcontractors, and
provided there shall exist no default of Tenant; provided however Tenant must
submit complete requisitions for such reimbursement for all but $94,000 of such
balance on or before the Reimbursement Date; and must submit complete
requisitions for the remaining $94,000 on or before October 15, 2009. Any
amounts for which Tenant shall not timely provide completed requisitions by the
aforesaid dates shall be forfeited.
12. Landlord represents that as of the date of this Amendment it holds fee
title to the Property and that no Superior Mortgage affects title thereto.
13. The parties agree that inasmuch as the Premises are comprised of the
Initial Space and the Expansion Space they are (together but not separately)
subject to Tenant's rights as set forth in Section 2.3.
-7-
14. Landlord hereby waives the net worth requirements of Section 6.2.1 of
the Lease which would otherwise apply to the merger of Predix into EPIX
Delaware, Inc. in consideration of the execution and delivery of this Amendment
and the execution and delivery of a guaranty of the Lease (as amended hereby) by
EPIX Pharmaceuticals, Inc. This waiver shall not apply to any subsequent events.
Notwithstanding any other provision of Section 6.2.1 of the Lease, Landlord
hereby acknowledges and agrees that the Premises may be occupied by Tenant and
EPIX Pharmaceuticals, Inc. without any additional notice by Tenant but only so
long as one is the parent of the other.
15. Tenant warrants and represents that it has dealt with no broker, other
than XxXxxx & Xxxx, Inc. and Xxxxxxx Xxxxx Xxxxx & Partners in connection with
the consummation of this Amendment, and in the event of any brokerage claims or
liens, against Landlord or the Building predicated upon or arising out of prior
deals with Tenant other than XxXxxx & Xxxx, Inc or Xxxxxxx Xxxxx Xxxxx &
Partners, Tenant agrees to defend the same and indemnify and hold Landlord
harmless against any such claim, and to discharge any such lien.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment under
seal as of the date first set forth above.
LANDLORD:
TRUSTEE OF 0 XXXXXXX XXXX REALTY TRUST
By: /s/ Xxxx X. Xxxxx
---------------------------------
Xxxx X. Xxxxx, as Trustee and not
individually
TENANT:
EPIX DELAWARE, INC.
By: /s/ Xxx X. Xxxxxxx
---------------------------------
Name: Xxx X. Xxxxxxx
Title: CFO
SECOND AMENDMENT TO LEASE
This is a Second Amendment to Lease (this "Amendment") dated as of June 2,
2008 by and between Trustees of 0 Xxxxxxx Xxxx Realty Trust under Declaration of
Trust dated January 30, 1998 and filed with Middlesex County Registry District
of the Land Court as Document No. 1054066 ("Landlord") and EPIX Delaware, Inc.,
a Delaware corporation ("Tenant").
WHEREAS, Landlord and Tenant (as successor-in-interest to Predix
Pharmaceutical Holdings, Inc.) are parties to a lease dated January 25, 2005, as
amended by a First Amendment to Lease (the "First Amendment") dated as of August
31, 2006 (as amended, the "Lease") pursuant to which Tenant has leased from
Landlord all of the rentable areas of the building located at 0 Xxxxxxx Xxxx,
Xxxxxxxxx, Xxxxxxxxxxxxx;
WHEREAS, the "Expansion Date," as defined in the First Amendment, occurred
on December 8, 2006 and the "Expansion Rent Date," as defined in the First
Amendment, occurred on January 7, 2007;
WHEREAS, the parties desire to correct a drafting error with respect to the
Annual Fixed Rent payable for the Initial Space and otherwise modify certain
terms and provisions of the Lease on the terms set forth in this Amendment.
NOW, THEREFORE, in consideration of the foregoing and for other
consideration the receipt and sufficiency of which are hereby mutually
acknowledged, Landlord and Tenant agree to amend the Lease as follows:
1. Capitalized terms used herein without definition shall have the meanings
ascribed to them by the Lease.
2. Section 1.1 of the Lease is amended by amending the following defined
terms contained therein to have the meanings hereinafter provided:
Original Term: Commencing on October 15, 2005 (the "Commencement Date") and
expiring on December 7, 2014.
Annual Fixed Rent: Annual Fixed Rent shall be the sum of the amounts set
forth below for the Initial Space and the Expansion Space and shall be in
addition to the amounts (which have been paid by Tenant) which were due pursuant
to Section 3.7 of the Lease for the period from June 1, 2005 through October 14,
2005.
Initial Space
December 15, 2005 - December 14, 2006 $474,543.99 ($16.29 per rentable square
foot of the Initial Space) per annum
December 15, 2006 - December 14, 2007 $569,511.05 ($19.55 per rentable square
foot of the Initial Space) per annum
-2-
December 15, 2007 - December 14, 2010 $728,275.00 ($25.00 per rentable square
foot of the Initial Space) per annum
December 15, 2010 - December 14, 2012 $801,102.50 ($27.50 per rentable square
foot of the Initial Space) per annum
December 15, 2012 - December 7, 2013 $975,888.50 ($33.50 per rentable square
foot of the Initial Space) per annum
December 8, 2013 - December 7, 2014 $1,005,019.50 ($34.50 per rentable
square foot of the Initial Space)
per annum
Expansion Space
January 7, 2007 - December 7, 2007 $577,526.00 ($20.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2007 - December 7, 2008 $802,902.00 ($28.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2008 - December 7, 2009 $831,074.00 ($29.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2009 - December 7, 2010 $859,246.00 ($30.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2010 - December 7, 2011 $887,418.00 ($31.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2011 - December 7, 2012 $915,590.00 ($32.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2012 - December 7, 2013 $943,762.00 ($33.50 per rentable square
foot of the Expansion Space) per annum
December 8, 2013 - December 7, 2014 $971,934.00 ($34.50 per rentable square
foot of the Expansion Space) per annum
3. Section 4.5 of the Lease is hereby amended to reflect the following:
(a) Notwithstanding anything contained in Section 4.5 to the contrary,
Landlord has, and shall continue to, furnish to the Property ordinary domestic
water (and associated sewer service) from the public utility in reasonable
quantities and Tenant has, and shall continue to, pay the cost thereof as part
of Operating Costs.
(b) Effective as of the Expansion Date, Tenant has, and shall continue to,
pay all costs of electricity supplied to the Property pursuant to the Lease,
within ten days of invoice
-3-
therefor. Notwithstanding the foregoing or any other provision of the Lease to
the contrary, at any time after December 31, 2009, Landlord may discontinue
contracting for a supply of electricity to the Property provided Landlord shall
have given Tenant not less than thirty (30) days notice prior thereto. If
Landlord exercises such right, from and after the effective date of such
discontinuance (i) Landlord shall not be obligated to furnish electricity to the
Property, and (ii) Tenant shall contract directly for a supply of electricity to
the Property and shall pay all bills therefor directly to the utility company
and Tenant also shall be responsible for, and shall pay directly, the cost of,
maintaining and repairing or replacing any meter or other device used to measure
electrical consumption at the Property.
4. Tenant warrants and represents that it has dealt with no broker in
connection with the consummation of this Amendment, and in the event of any
brokerage claims or liens, against Landlord or the Building predicated upon or
arising out of prior dealing with Tenant, Tenant agrees to defend the same and
indemnify and hold Landlord harmless against any such claim, and to discharge
any such lien.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment under
seal as of the date first set forth above.
LANDLORD:
TRUSTEES OF 0 XXXXXXX XXXX REALTY TRUST
By: /s/ Xxxx X. Xxxxxx
------------------------------------
Xxxx X. Xxxxxx, as Trustee and
not individually
TENANT:
EPIX DELAWARE, INC.
By: /s/ Xxx Xxxxxxxx Xxxxxxx
------------------------------------
Name: Xxx Xxxxxxxx Xxxxxxx
Title: CFO
