Exhibit 10.1
An asterisk ([*]) indicates that confidential information has been
omitted and filed separately with the Securities and Exchange Commission as
part of a Confidential Treatment Request.
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
BY AND BETWEEN
AES RED OAK, L.L.C.
AND
XXXXXXXX ENERGY MARKETING & TRADING COMPANY
Dated September 17, 1999
TABLE OF CONTENTS
PAGE
ARTICLE I: DEFINITIONS AND INTERPRETATION.........................................................................1
SECTION 1.1 Definitions....................................................................................1
SECTION 1.2 Interpretation................................................................................16
ARTICLE II: TERM.................................................................................................16
SECTION 2.1 Term..........................................................................................16
SECTION 2.2 Commercial Operation Date.....................................................................16
ARTICLE III: PURCHASE OF FUEL CONVERSION SERVICES...............................................................18
SECTION 3.1 Delivery of Natural Gas.......................................................................18
SECTION 3.2 Fuel Conversion Services......................................................................18
SECTION 3.3 Fuel Conversion Option Demand Payment.........................................................18
SECTION 3.4 Costs and Expenses............................................................................18
SECTION 3.5 Energy Exercise Fee...........................................................................19
SECTION 3.6 Adjustments...................................................................................19
SECTION 3.7 Variable O&M Payments.........................................................................19
SECTION 3.8 Facility Heat Rate Bonus or Credits...........................................................19
SECTION 3.9 Alternative Delivery Point....................................................................19
ARTICLE IV: PURCHASE AND SALE OF UNFORCED CAPACITY...............................................................20
SECTION 4.1 Sale of Temperature Adjusted Unforced Capacity................................................20
SECTION 4.2 Additional and Expansion Capacity.............................................................20
ARTICLE V: PROJECT DEVELOPMENT...................................................................................21
SECTION 5.1 Progress Reporting............................................................................21
SECTION 5.2 Establishing Facility Capacity................................................................21
SECTION 5.3 Required Permits and Approvals................................................................22
SECTION 5.4 Access to Site................................................................................22
ARTICLE VI: INITIAL START UP TESTING, TESTING AND COMMERCIAL OPERATION...........................................22
SECTION 6.1 Other Sales of Energy.........................................................................22
SECTION 6.2 Purchase of Natural Gas.......................................................................23
SECTION 6.3 Gas Price.....................................................................................23
SECTION 6.4 Replacement Index.............................................................................23
SECTION 6.5 Notice of Commercial Operation Date...........................................................23
SECTION 6.6 Demonstration of Facility Capacity............................................................23
ARTICLE VII: INTERCONNECTION AND METERING EQUIPMENT..............................................................24
i
TABLE OF CONTENTS
PAGE
SECTION 7.1 Responsibility for Interconnection Facilities.................................................24
SECTION 7.2 Amendment of Interconnection Agreement........................................................24
SECTION 7.3 Gas Interconnection...........................................................................25
ARTICLE VIII: OPERATION AND DISPATCH.............................................................................26
SECTION 8.1 Operation Standards...........................................................................26
SECTION 8.2 Parallel Operation............................................................................26
SECTION 8.3 Disconnection by Host Utility.................................................................26
SECTION 8.4 Automatic Regulation..........................................................................27
SECTION 8.5 Energy and Ancillary Nominations and Confirmations............................................27
SECTION 8.6 Right to Energy and Ancillary Services........................................................27
SECTION 8.7 Facility Availability Status..................................................................28
SECTION 8.8 Combined Cycle Operation......................................................................29
SECTION 8.9 O&M Contractor................................................................................29
SECTION 8.10 Delivery to Facility.........................................................................29
SECTION 8.11 Natural Gas Nominations and Scheduling.......................................................29
SECTION 8.12 Imbalance Prevention.........................................................................29
SECTION 8.13 Transporter Penalties........................................................................30
SECTION 8.14 Actual Flow of Natural Gas...................................................................30
ARTICLE IX: MAINTENANCE.........................................................................................30
SECTION 9.1 Maintenance Standards.........................................................................30
SECTION 9.2 Maintenance Certification.....................................................................31
SECTION 9.3 Records of Outage Statistics..................................................................31
SECTION 9.4 Operations Forecasts..........................................................................31
ARTICLE X: METERING, BILLING, PAYMENT AND TAXES..................................................................32
SECTION 10.1 Generally....................................................................................32
SECTION 10.2 Metering of Net Electric Energy..............................................................32
SECTION 10.3 Metering of Natural Gas......................................................................33
SECTION 10.4 Monthly Statements...........................................................................33
SECTION 10.5 Record Retention.............................................................................35
SECTION 10.6 Maintenance and Testing of Gas Metering Equipment............................................36
SECTION 10.7 Responsibility for Taxes.....................................................................36
SECTION 10.8 Fuel Conversion Volume Rebate and Non-Dispatch Payments......................................38
ARTICLE XI: DISPUTE RESOLUTION...................................................................................39
SECTION 11.1 Third Party Engineer.........................................................................39
SECTION 11.2 Designated Representatives...................................................................40
ii
TABLE OF CONTENTS
PAGE
SECTION 11.3 Arbitration..................................................................................41
SECTION 11.4 Survival of Article..........................................................................42
ARTICLE XII: REPRESENTATIONS, WARRANTIES AND COVENANTS...........................................................42
SECTION 12.1 By Seller....................................................................................42
SECTION 12.2 By Xxxxxxxx..................................................................................43
ARTICLE XIII: LIABILITY, DEDICATION..............................................................................44
SECTION 13.1 Third Parties................................................................................44
SECTION 13.2 Limitation of Liability......................................................................44
SECTION 13.3 No Dedication to the Public..................................................................44
ARTICLE XIV: INDEMNITY...........................................................................................44
SECTION 14.1 Indemnity....................................................................................44
SECTION 14.2 Environmental Indemnity......................................................................45
SECTION 14.3 Claims by Employees..........................................................................46
SECTION 14.4 Risk of Loss.................................................................................47
SECTION 14.5 Survival of Article..........................................................................47
ARTICLE XV: INSURANCE............................................................................................47
SECTION 15.1 Insurance Generally..........................................................................47
SECTION 15.2 Risk Insurance...............................................................................48
SECTION 15.3 Copies.......................................................................................48
ARTICLE XVI: FORCE MAJUERE.......................................................................................49
SECTION 16.1 Excused Performance..........................................................................49
SECTION 16.2 Exclusions from Force Majeure................................................................50
SECTION 16.3 Labor Disputes...............................................................................51
SECTION 16.4 Termination from Force Majeure...............................................................51
SECTION 16.5 Extension from Force Majeure.................................................................51
ARTICLE XVII: EVENTS OF DEFAULT; TERMINATION, REMEDIES...........................................................51
SECTION 17.1 Events of Default............................................................................51
SECTION 17.2 Cure and Termination.........................................................................53
ARTICLE XVIII: SECURITY..........................................................................................54
SECTION 18.1 Indemnity for Delay..........................................................................54
SECTION 18.2 Seller's Guaranty............................................................................54
SECTION 18.3 Xxxxxxxx Guaranty............................................................................55
SECTION 18.4 Option to Bind...............................................................................56
iii
TABLE OF CONTENTS
PAGE
ARTICLE XIX: SEVERAL OBLIGATIONS.................................................................................57
SECTION 19.1 Several Obligations..........................................................................57
ARTICLE XX: WAIVER...............................................................................................57
SECTION 20.1 No Continuing Waiver.........................................................................57
ARTICLE XXI: ASSIGNMENT..........................................................................................57
SECTION 21.1 Assignment...................................................................................57
SECTION 21.2 Transfer of Facility.........................................................................58
SECTION 21.3 Void Assignments or Transfers................................................................58
SECTION 21.4 Cost Reimbursement...........................................................................58
ARTICLE XXII: NOTICES............................................................................................59
SECTION 22.1 Notice Requirements..........................................................................59
SECTION 22.2 Timing.......................................................................................59
ARTICLE XXIII: GRATUITIES........................................................................................59
SECTION 23.1 No Gratuities................................................................................59
ARTICLE XXIV: CAPTIONS...........................................................................................60
SECTION 24.1 Captions.....................................................................................60
ARTICLE XXV: CHOICE OF LAWS......................................................................................60
SECTION 25.1 Choice of Laws...............................................................................60
ARTICLE XXVI: MISCELLANEOUS PROVISIONS...........................................................................61
SECTION 26.1 Access and Confidentiality...................................................................61
SECTION 26.2 Survival.....................................................................................61
SECTION 26.3 Cost Responsibility..........................................................................62
SECTION 26.4 No Third Party Rights........................................................................62
SECTION 26.5 Announcements................................................................................62
SECTION 26.6 Support of Financing.........................................................................62
SECTION 26.7 Right to Purchase Facility...................................................................62
SECTION 26.8 Assignment of Third Party Agreements.........................................................62
SECTION 26.9 Examination of Records.......................................................................63
SECTION 26.10 Successors and Assigns......................................................................63
SECTION 26.11 Counterparts................................................................................63
SECTION 26.12 Entire Agreement............................................................................63
SECTION 26.13 Severability................................................................................63
iv
TABLE OF CONTENTS
PAGE
SECTION 26.14 Modification in Writing.....................................................................63
SECTION 26.15 Emissions Allowances........................................................................64
SECTION 26.16 Xxxxxxxx' Right to Intertie.................................................................64
v
TABLE OF APPENDICES
1. PRICING
2. CONFIDENTIALITY AGREEMENT
3. EXEMPT WHOLESALE GENERATOR CERTIFICATION
4.A. PRELIMINARY SINGLE-LINE DIAGRAM SHOWING NATURAL GAS DELIVERY POINTS
4.B. PRELIMINARY SINGLE-LINE DIAGRAM SHOWING ELECTRIC DELIVERY POINTS
5. FORM OF GUARANTY BY THE AES CORPORATION
6. FORM OF GUARANTY BY THE XXXXXXXX COMPANIES, INC.
7. LIST OF THIRD PARTY ENGINEERS
8. BILLING TEMPLATE
9. OPERATING SPECIFICATIONS
vi
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
THIS FUEL CONVERSION SERVICES, CAPACITY AND ANCILLARY SERVICES PURCHASE
AGREEMENT (together with the Appendices hereto, this "Agreement"), dated as of
September 17, 1999, by and between AES Red Oak, L.L.C., a Delaware limited
liability company ("Seller"), and Xxxxxxxx Energy Marketing & Trading Company, a
corporation organized and existing under the laws of the State of Delaware
("Xxxxxxxx"), (Seller and Xxxxxxxx hereinafter referred to individually as a
"Party" and collectively as the "Parties").
WITNESSETH:
WHEREAS, Xxxxxxxx is engaged in the purchase of fuel conversion
services to obtain electric energy for sale and the purchase of capacity and
ancillary services; and
WHEREAS, Seller will own, operate and maintain the Facility (as
hereinafter defined) to be located at the Site (as hereinafter defined); and
WHEREAS, Seller proposes to qualify the Facility as an exempt wholesale
generator under the applicable rules of the Federal Energy Regulatory Commission
("FERC"); and
WHEREAS, Xxxxxxxx intends to deliver Natural Gas (as hereinafter
defined) to the Facility in accordance with this Agreement; and
WHEREAS, Seller desires to sell and Xxxxxxxx desires to purchase
Unforced Capacity (as hereinafter defined), Ancillary Services (as hereinafter
defined) and Fuel Conversion Services (as hereinafter defined) under the terms
and conditions hereinafter set forth.
NOW, THEREFORE, in consideration of the mutual covenants and promises
set forth below, the Parties hereto, intending to be legally bound, hereby
covenant, promise and agree as follows:
ARTICLE I: DEFINITIONS AND INTERPRETATION
SECTION 1.1 Definitions
For purposes of this Agreement, the following definitions shall apply
unless the context clearly indicates otherwise. All capitalized terms used in
this Agreement that are not defined in this Article I shall have the definitions
contained elsewhere herein, including the Appendices hereto.
1
"ACCEPTED ELECTRICAL PRACTICES" - those practices, methods and acts
engaged in or approved by a significant portion of the electric utility industry
during the relevant time period, or any of the practices, methods and acts
which, in exercise of reasonable judgment in light of the facts known at the
time a decision is made, that could have been expected to accomplish a desired
result at reasonable cost consistent with good business practices, reliability,
safety and expedition. Accepted Electrical Practices are not intended to be
limited to the optimum practices, methods or acts to the exclusion of others,
but rather to those practices, methods and acts generally accepted or approved
by a significant portion of the electric utility industry in the relevant
region, during the relevant time period, as described in the immediately
preceding sentence.
"AFFILIATE" - with respect to any specified Person, any other Person
directly or indirectly controlling or controlled by or under direct or indirect
common control with such specified Person. For purposes of this definition,
"control" (including, with correlative meanings, the terms "controlling,"
"controlled by" and "under common control with"), as used with respect to any
Person, shall mean the possession, directly or indirectly, of the power to
direct or cause the direction of the management or policies of such Person,
whether through the ownership of voting securities, by agreement or otherwise.
"ALLOCATED START-UP DURATION" - the time period required by Seller to
permit a Cold Start, Warm Start or Hot Start of the Facility as Scheduled for a
Dispatch Period under normal Facility equipment conditions. Such period of time
will be set initially based on the engineering, construction and procurement
contractor's guidelines, which shall be provided by Seller to Xxxxxxxx promptly
after receipt by Seller of such guidelines from the engineering, procurement and
construction contractor but in any event no later than the Commercial Operation
Date, and revised by the Parties after the first Contract Year to reflect actual
operating experience; provided, however, that such revised periods shall be
within [*] of the engineering, construction and procurement contractor's
guidelines.
"ALTERNATIVE DELIVERY POINT" - any physical point on the transmission
system operated by PJM, other than the Primary Delivery Point, that is mutually
agreed to by the Parties pursuant to Section 3.9 at which Seller may deliver or
cause to be delivered Energy and/or Ancillary Services and at which Xxxxxxxx
shall receive such Energy and/or Ancillary Services.
"ANCILLARY SERVICES" - those services which the Facility is capable of
providing that are defined or described as "Ancillary Services" in the PJM
Tariff and in the event such PJM Tariff does not exist, then those similar or
related services to the extent commonly sold or saleable (or used or usable) in
the electric power generation or transmission industry within the PJM market
from time to time.
"ANTICIPATED COMMERCIAL OPERATION DATE" - has the meaning given such
term in Section 2.2.
2
"AUTOMATIC REGULATION" - the capability of a Unit to increase or
decrease automatically its megawatt output from a set point in response to a
control signal from a remote operations center. Such capability to regulate will
be set initially based on the engineering, construction and procurement
contractor's guidelines, which shall be provided by Seller to Xxxxxxxx promptly
after receipt by Seller of such guidelines from the engineering, procurement and
construction contractor but in any event no later than the Commercial Operation
Date, and revised by the Parties after the first Contract Year to reflect actual
operating experience; provided, however, that such revised capability shall be
within [*] of the engineering, construction and procurement contractor's
guidelines provided prior to the Commercial Operation Date.
"BACK-UP ELECTRIC METERING EQUIPMENT" - metering equipment comparable
to the Electric Metering Equipment.
"BEGINNING REQUESTED DISPATCH HOUR" - the first clock hour during which
the Facility is Scheduled to deliver Net Electric Energy and/or Ancillary
Services during a Dispatch Period.
"BILLING MONTH" - except for the first such period under this
Agreement, which may be shorter, one-twelfth (1/12) of a year, or the period of
approximately thirty (30) Days between two (2) regular consecutive readings of
the Host Utility's electric meter or meters, but not less than twenty-six (26)
Days and not more than thirty-five (35) Days.
"BTU" - the quantity of heat required to raise the temperature of one
pound of water one degree Fahrenheit at 60 degrees Fahrenheit.
"BUSINESS DAY" - any Day on which the Federal Reserve Bank of New York,
New York is open for business.
"CAPACITY RESOURCE" - net capacity from owned (or contracted)
generating resources which are designated and committed by a Load Serving
Entity, as defined in the Reliability Assurance Agreement, to serve its
obligations under the Reliability Assurance Agreement or generating resources
that have otherwise been accredited as "Capacity Resources" under procedures
adopted and implemented by PJM.
"CENTRAL PREVAILING TIME" - the time in the central time zone of the
United States.
"COLD START" - a start of a Unit in Combined Cycle Mode given that all
of the breakers of that Unit's combustion turbine generator have been open for
at least the previous [*].
"COMBINED CYCLE MODE" - the simultaneous operation of a combustion
turbine(s), heat recovery steam generator(s) and steam turbine for the purpose
of producing Net Electric Energy.
3
"COMMERCIAL OPERATION DATE" - the Day on which (i) the Initial Start-Up
Testing of the Facility has been successfully completed to the satisfaction of
Seller and Xxxxxxxx has received written notice thereof from Seller, (ii) Seller
has received all approvals necessary for it to make the sales contemplated
hereunder to Xxxxxxxx, and (iii) Seller has obtained all required permits and
authorizations for operation of the Facility.
"CONTRACT ANNIVERSARY DATE" - the last Day of the month in which the
Commercial Operation Date occurs and each succeeding anniversary of such Day
throughout the Term of this Agreement.
"CONTRACT QUANTITY" - the temperature adjusted contract quantity of
Energy Xxxxxxxx shall be obligated to receive according to its Dispatch Notice
which shall be up to 764.3 MWh/h [*] and, in accordance with Appendix 9,
the allowable dispatch curve. The Contract Quantity will be adjusted annually
based on PJM's facility output test or rating.
"CONTRACT YEAR" - the twelve months ending on the Contract Anniversary
Date of each year except for the first Contract Year which shall also include
any portion of the month between the Commercial Operation Date and the end of
the month in which the Commercial Operation Date occurs.
"DAILY GAS INDEX" - has the meaning given such term in the definition
of Gas Price.
"DAY" - a period of twenty-four (24) consecutive hours, beginning at
12:01 a.m. Eastern Prevailing Time.
"DISPATCH" - the act of directing a Unit(s) or the Facility to generate
Net Electric Energy and/or Ancillary Services, pursuant to a Dispatch Notice.
"DISPATCH NOTICE" - a notice delivered to Seller by or on behalf of
Xxxxxxxx directing the Dispatch of the Facility for a specific Dispatch Period
and quantity of Energy and/or Ancillary Services effective until the delivery of
a subsequent Dispatch Notice and in a form to be agreed to by the Parties no
later than twelve (12) months after the Execution Date, provided that when such
notice is given telephonically it shall be promptly confirmed in writing by
facsimile or electronic transmission.
"DISPATCH OPERATION" - the operation of the Facility at the direction
of Xxxxxxxx.
"DISPATCH PERIOD" - a period of time during which Xxxxxxxx has
requested delivery of Net Electric Energy and/or the provision of Ancillary
Services starting with a Beginning Requested Dispatch Hour and concluding with
an Ending Requested Dispatch Hour. A Dispatch Period may continue for more than
one calendar Day.
4
"DUFF & XXXXXX" - Xxxx & Xxxxxx Credit Rating Company, a company
headquartered in Chicago, Illinois that provides ratings and research on
corporate financings.
"EARLY SHUTDOWN NOTICE" - a notice provided by Xxxxxxxx to Seller
during a Dispatch Period requesting an earlier Ending Requested Dispatch Hour of
a Unit(s) or the Facility than that specified in the Dispatch Notice which
commenced such Dispatch Period, provided that such earlier Ending Requested
Dispatch Hour shall not be any sooner than one (1) hour after receipt by Seller
of such Early Shutdown Notice.
"EASTERN PREVAILING TIME" - the time in the eastern time zone of the
United States.
"ELECTRIC METERING EQUIPMENT" - electric meters and associated
equipment, which shall be owned by the Host Utility and operated and maintained
in accordance with the Interconnection Agreement, including, without limitation,
metering transformers and meters for measuring kilowatt-hours and reactive
volt-ampere hours, utilized in determining the amount of Net Electric Energy
and/or Ancillary Services delivered by Seller to the Primary Delivery Point
under this Agreement.
"EMERGENCY(IES)" - a condition(s) or situation(s) which the Host
Utility, PJM or Seller reasonably deems imminently likely to endanger life or
property including the Facility; or imminently likely to impair or adversely
affect the Host Utility's electrical system or the electrical systems of others
to which the Host Utility's electrical system is directly or indirectly
connected. Such a condition or situation may include, but is not limited to, a
forced outage of the Host Utility's electrical system, potential overloading of
the Host Utility's transmission and/or distribution circuits, unusual operating
conditions on either the Host Utility's or Seller's electrical system or
conditions such that the Host Utility is unable to accept Net Electric Energy
from the Facility without jeopardizing the Facility, the Host Utility's
electrical system or the electrical systems of others to which the Host
Utility's electrical system is directly or indirectly connected.
"ENDING REQUESTED DISPATCH HOUR" - the last clock hour during which the
Facility is Scheduled to deliver Net Electric Energy or Ancillary Services
during a Dispatch Period.
"ENERGY" - electric energy measured in MWh (whole or in part) that
meets or exceeds the specifications of the Regional Transmission Owner in effect
at the time the Energy is delivered to the Primary Delivery Point or Alternative
Delivery Point.
"ENERGY EXERCISE FEE" - has the meaning given to such term in Appendix
1, Section II, A.3.
"ENVIRONMENTAL LAW" - any applicable federal, state, local or other
governmental legal requirement governing or relating to (i) the environment,
(ii) releases or threatened releases of Hazardous Materials including, without
limitation,
5
investigations, monitoring and abatement of such releases, and (iii) the
manufacture, handling, transport, use, treatment, storage or disposal of
Hazardous Materials or materials containing Hazardous Materials.
"EXECUTION DATE" - the date set forth in the preamble to this
Agreement.
"EXPANSION CAPACITY" - an increase in the amount of electric generating
capacity located on the Site but not a part of the Facility.
"FACILITY" - the combined cycle electric generating facility located in
Sayreville, New Jersey, with a design electric generating capacity of
approximately 764.3 MW [*] at [*]. Fahrenheit consisting of three (3)
501 "F" type combustion turbines, three (3) heat recovery steam generators and
one (1) steam turbine, with evaporative cooling on the inlet air flow, together
with all of the parts, instruments, appurtenances, accessories and other
property that may be installed in or attached to or otherwise become part of
such facility. The Facility is comprised of two bus bars. Bus bar 1 (two (2)
combustion turbines and one (1) auxiliary station) receives approximately 350
MW. Bus bar 2 (one (1) steam turbine, one (1) combustion turbine and one (1)
auxiliary station) receives approximately 410 MW.
"FACILITY CAPACITY" - the actual total net MW generating capability of
the Facility measured at the Primary Delivery Point when operating on Natural
Gas in Combined Cycle Mode at [*]. Fahrenheit as established during Initial
Start-Up Testing of the Facility and as demonstrated and adjusted from time to
time pursuant to Section 6.6.
"FACILITY TESTING" - Seller's operation and testing of the Facility,
including performance tests, to determine, among other things, the operating
characteristics of the Facility, the Facility Capacity and the Facility's
ability to meet Seller's obligations pursuant to this Agreement; provided that
any transmission costs associated with Initial Start-Up Testing shall be paid by
Seller.
"FERC" - the Federal Energy Regulatory Commission or any successor
agency thereto.
"FINAL CO DATE" - has the meaning given such term in Section 2.2(c).
"FIRST PAID EXTENSION OPTION" - has the meaning given such term in
Section 2.2(a).
"FORCE MAJEURE" - [*]
6
[*]
"FORCED OUTAGE" - a "Generator Forced Outage" as defined in the PJM
Agreement. Forced Outages include:
"TOTAL FORCED OUTAGE" - during periods other than Planned
Outages or Maintenance Outages, the Facility is unable to engage in
Dispatch Operation, or the Facility is declared by Seller to be in a
Total Forced Outage for what would otherwise be a Partial Forced
Outage.
"PARTIAL FORCED OUTAGE" - during periods other than Planned
Outages or Maintenance Outages, the Facility is partially able to
engage in Dispatch Operation, and has not been declared by Seller to be
in a Total Forced Outage.
"FREE EXTENSION OPTION" - has the meaning given such term in Section
2.2(a).
"FUEL CONVERSION OPTION DEMAND CHARGE" - a fixed monthly amount as set
forth on Appendix 1, Section II, A.2, Table I attached hereto.
"FUEL CONVERSION OPTION DEMAND PAYMENT" - the product of the Fuel
Conversion Option Demand Charge and the Facility Capacity, which is to be paid
by Xxxxxxxx to Seller as set forth in Xxxxxxxx 0, Xxxxxxx XX, X.0.
"FUEL CONVERSION SERVICES" - (i) operation of the Facility by Seller
to combust the Natural Gas delivered by Xxxxxxxx in order to generate and
deliver at the Primary Delivery Point Net Electric Energy or to provide at the
Primary Delivery Point Ancillary Services or (ii) the provision of Energy or
Ancillary Services in accordance with Section 3.9.
"FUEL CONVERSION VOLUME REBATE" - has the meaning given such term in
Section 10.8.
"FULLY AVAILABLE" - any time the Facility is not in a Forced Outage,
Maintenance Outage, Partial Outage or Planned Outage and capable of producing
100% of the Facility Capacity and Ancillary Services.
"GAS DAILY" - the daily publication referred to herein published by FT
Energy.
7
"GAS DAY" -- A period of 24 consecutive hours beginning at 9 A.M.
Central Prevailing Time.
"GAS PRICE" -- if Natural Gas is Scheduled during the Gas Day prior
to expected flow, the Gas Price shall be the sum of the price published by
GAS DAILY for Natural Gas to flow on such Gas Day under the heading "Daily
Price Survey" and under the column heading "Midpoint" for the point "Transco
Z6 (NY)" (the "Daily Gas Index"), plus applicable Transportation Charges from
the reference point for the Daily Gas Index to the Facility, plus [*]; if
Natural Gas is Scheduled during the same Gas Day of expected flow the price
shall be the market price as determined by Xxxxxxxx in a commercially
reasonable manner for Natural Gas delivered for the reference point "Transco
Z6 (NY)" (the "Intraday Gas Price") plus applicable Transportation Charges
from the reference point for the Daily Gas Index to the Facility.
"GDPIPD" -- the annual Gross Domestic Product Implicit Price
Deflator as reported by the United States Department of Commerce, Bureau of
Economic Analysis monthly in the SURVEY OF CURRENT BUSINESS (Index base 1992
= 100).
"GPU" -- Metropolitan Edison Company, Pennsylvania Electric Company
and Jersey Central Power and Light Company, collectively doing business as
GPU Energy, Inc., and their Affiliates.
"GUARANTY AMOUNT" -- has the meaning given such term in Section 18.4.
"HAZARDOUS MATERIALS" -- any petroleum or petroleum products,
radioactive materials, asbestos in any form that is or could become friable,
urea formaldehyde foam insulation, transformers or other equipment that
contain dielectric fluid containing polychlorinated biphenyls ("PCBs") and
any other chemicals, materials or substances which are now or hereafter
become defined as or included in the definition of "hazardous substances,"
"hazardous wastes," "hazardous materials," "extremely hazardous wastes,"
"restricted hazardous wastes," "toxic substances" or "toxic pollutants"
under, or are regulated or become regulated as such by Environmental Laws,
including but not limited to the Comprehensive Environmental Response,
Compensation, and Liability Act of 1980, as amended (42 U.S.C. Section 9601
ET SEQ.); the Hazardous Material Transportation Act, as amended (42 U.S.C
Section 1801 ET SEQ.); the Resource Conservation and Recovery Act, as amended
(42 U.S.C. Section 6901 ET SEQ.); the Toxic Substances Control Act, as
amended (15 U.S.C. Section 2601); the Clean Air Act, as amended (42 U.S.C
Section 7401 ET SEQ.); the Federal Water Pollution Control Act, as amended
(33 U.S.C. Section 1251 ET SEQ.); or in the regulations promulgated pursuant
to said laws.
"HEAT RATE" -- the actual Facility fuel efficiency performance while
operating in Combined Cycle Mode and on Natural Gas (expressed in Btu per kWh
(HHV)). Prior to the Commercial Operation Date, Seller shall provide, for
information purposes only, Xxxxxxxx with Heat Rate curves for the Facility,
when said curves are reasonably available, which show expected changes to the
Heat Rate due to changes in ambient
8
temperature and other conditions. Seller also shall inform Xxxxxxxx of any
material changes in the expected Heat Rate of the Facility.
"HEAT RATE TARGET" -- shall be [*] Btu per kWh (HHV). If Xxxxxxxx
issues a Dispatch Notice for less than the Facility Capacity then the Heat
Rate Target will be in accordance with the Heat Rate curve that shows the
Heat Rate Target at other allowable dispatch levels which shall be included
herein as Appendix 9. In all cases such Heat Rate Target shall be adjusted as
appropriate to account for the provision of Ancillary Services which affect
Heat Rate. Seller will provide Xxxxxxxx such curve as soon as reasonably
practicable but in no event later than the Commercial Operation Date.
"HHV" -- higher heating value.
"HOST UTILITY" -- Jersey Central Power & Light Company, which also
does business as GPU Energy, or its successor.
"HOT START" -- a start of a Unit in Combined Cycle Mode given that
all of the breakers of that Unit's combustion turbine generator have been
open for no more than [*].
"IMBALANCE" -- has the meaning given such term in Section 8.12.
"INITIAL START-UP TESTING" -- Seller's operation and testing of the
Facility prior to the Commercial Operation Date, including performance tests,
to determine, among other things, the operating characteristics of the
Facility, the Facility Capacity and the Facility's ability to meet Seller's
obligations pursuant to this Agreement; provided that any transmission costs
associated with Initial Start-Up Testing shall be paid by Seller.
"INTERCONNECTION AGREEMENT" -- that certain agreement between Seller
and Host Utility dated April 27, 1999.
"INTERCONNECTION FACILITIES" -- all structures, facilities,
equipment, auxiliary equipment, devices and apparatus including the
Protective Apparatus directly or indirectly required and installed to
interconnect and deliver Net Electric Energy and Ancillary Services from the
Facility to the Primary Delivery Point, including, but not limited to,
electric transmission and/or distribution lines, transformation, switching,
Electric Metering Equipment, any other metering equipment, communications,
and safety equipment, including, but not limited to, equipment required to
protect (i) the Host Utility's electrical system and its customers from
faults occurring at the Facility, and (ii) the Facility from faults occurring
on the Host Utility's electrical system or on the electrical systems of
others to which the Host Utility's electrical system is directly or
indirectly connected.
"INVESTMENT GRADE" -- a rating in one of the four highest categories
(without regard to subcategories within such rating categories) by Standard &
Poor's or Xxxxx'x.
9
"kW" -- kilowatt
"kWh" -- kilowatt-hour.
"LATE PAYMENT INTEREST RATE" -- the Prime Rate plus one (1) percent
per annum.
"LENDER" -- any financial institution, Person, bondholder or
noteholder which provides debt or equity capital, loans, credit or credit
support, acts as counterparty on any interest rate or currency hedging
arrangements or provides other financing to Seller in respect of the
acquisition, ownership, construction, operation or maintenance of the
Facility; such term also includes any such financial institution, Person,
bondholder or noteholder which acts in the capacity of "Lender" in connection
with any refinancing by Seller of its then outstanding debt obligation.
"LOAD SERVING ENTITY" -- any entity (or the duly designated agent of
such entity), including a load aggregator or power marketer, (i) serving
end-users within the PJM control area, and (ii) that has been granted the
authority or has an obligation pursuant to state or local law, regulation or
franchise to sell electric energy to end-users located within the PJM control
area.
"LOCATIONAL MARGINAL PRICE" OR "LMP" -- the hourly integrated market
clearing marginal price (exclusive of any price for Unforced Capacity from
Capacity Resources), expressed in $/MWh, for electric energy at a location
where energy is delivered or received, calculated pursuant to the terms of
the PJM Agreement. In the event that LMP becomes unavailable or ceases to be
made available, the Parties shall use good faith efforts to agree upon a
Replacement Price. If the parties cannot agree on a substitute methodology to
determine price by the end of the first month for which the Replacement Price
could not be determined, then Xxxxxxxx and Seller shall each prepare a list
of three alternative published reference postings of spot prices for Net
Electric Energy delivered in the same geographic area as the Primary Delivery
Point. Each list shall set forth the highest priority posting first. Each
Party shall submit its list to the other within ten (10) days after the end
of the first month for which the price could not be determined. The first
posting appearing on Seller's list that also appears on Xxxxxxxx' list shall
constitute the new price effective as of the date that the Parties ceased
using LMP.
"LOSS" -- has the meaning given such term in Section 14.1.
"MAINTENANCE OUTAGE" -- the Scheduled removal of the Facility, or a
portion thereof, from service in order to perform necessary repairs on
specific components of the Facility where removal of the Facility could be
postponed to the weekend past the immediately succeeding weekend. In the case
of conflict, the definition of "Generator Maintenance Outage" as defined in
the PJM Agreement shall control.
"MAJOR MAINTENANCE RESERVE ACCOUNT" -- has the meaning given such
term in Section 10.8(b).
10
"MINIMUM UTILIZATION CHARGE" -- has the meaning given such term in
Appendix 1, Section II, A.2.
"XXXXX'X" -- Xxxxx'x Investors Services, Inc., and its successors.
"MMBtu" -- One Million Btus
"MW" -- megawatt.
"MWh" -- megawatt-hour.
"NATURAL GAS" -- merchantable Natural Gas that meets the quality
specifications set forth in the applicable Transporter's tariff.
"NATURAL GAS DELIVERY POINT" -- each of the physical point(s)
identified on Appendix 4.A at which Natural Gas is delivered and measured.
"NATURAL GAS INTERCONNECTION FACILITIES" -- has the meaning given
such term in Section 7.3.
"NATURAL GAS METERING EQUIPMENT" -- gas meters and associated
equipment utilized in determining (i) the amount of Natural Gas delivered to
Seller by Xxxxxxxx under this Agreement, and (ii) the amount of Natural Gas
consumed by the Facility.
"NET ELECTRIC ENERGY" -- the gross amount of electric energy
generated by the Facility at Xxxxxxxx' direction, less station service
requirements and any transformation and transmission line Losses to the
Primary Delivery Point and delivered by Seller to the Host Utility's electric
system at the Primary Delivery Point.
"NEW TAXES" -- (i) any Taxes or modifications therein enacted and
effective after the Execution Date, including, without limitation, that
portion of any Taxes or New Taxes that constitutes an increase in the rate
thereof (but excluding an increase in the value of the base upon or from
which computed), or (ii) any law, order, rule or regulation, or official
interpretation thereof; enacted and effective after the Execution Date
resulting in application of any Taxes to a new or different class of Persons.
"NON-DISPATCH COST" -- has the meaning given such term in Appendix
1, Section V.
"NON-DISPATCH PAYMENT" -- has the meaning given such term in
Appendix 1, Section V.
"NON-PEAK PERIOD" -- the months other than the months comprising
the Summer Peak Period and Winter Peak Period.
11
"PARTIALLY AVAILABLE" -- has the meaning given such term in Appendix
1, Section V.
"PEAK HOURS" -- 7:00 AM Eastern Prevailing Time to 11:00 PM Eastern
Prevailing Time, Monday through Friday except for non-Business Days.
"PERMITTED LIEN" -- any Lien (i) for current Taxes not delinquent,
(ii) for an immaterial amount or in connection with any immaterial matter, in
either case arising in the ordinary course of business and which, together
with all other Liens described in this clause (iii), does not materially
affect or interfere with the present or intended value or use of the affected
property or (iv) securing the loans to Seller permitted by this Agreement
with respect to the construction, ownership and operation of the Facility or
any permitted refinancings thereof.
"PERSON" -- any individual, corporation, limited liability company,
partnership, limited partnership, trust, association or other entity.
"PJM" -- the PJM Interconnection, L.L.C., acting in accordance with
the PJM Agreement or the applicable successor entity.
"PJM AGREEMENT" -- that certain Amended and Restated Operating
Agreement of PJM Interconnection, L.L.C., dated as of June 2, 1997, and
applicable portions of the PJM Manuals, as further amended, revised or
superseded from time to time.
"PJM MANUALS" -- the instructions, rules, procedures and guidelines
established by PJM for the operation, planning and accounting requirements of
the PJM control area and the PJM energy market.
"PJM TARIFF" -- the PJM Open Access Transmission Tariff as on file
with FERC and in effect from time to time, including any Schedules,
appendices, or exhibits attached thereto.
"PLANNED OUTAGE" -- a complete or partial outage of the Facility
that has been Scheduled in accordance with Section 9.4(b) hereof.
"POSITION NOTICE" -- has the meaning given such term in Section
11.1(a).
"PRIMARY DELIVERY POINT" -- the physical points set forth as
Appendix 4.B at which Net Electric Energy and/or Ancillary Services are to be
delivered and measured.
"PRIME RATE" -- the prime commercial lending rate announced by
Citibank, N.A., as in effect from time to time.
"PROTECTIVE APPARATUS" -- such equipment and apparatus on Seller's
side of the Primary Delivery Point, including, but not limited to, protective
relays, circuit breakers
12
and the like, necessary or appropriate to isolate the Facility from the Host
Utility's electrical system consistent with Accepted Electrical Practices.
"PROTECTIVE GAS APPARATUS" -- such equipment and apparatus on
Seller's side of the Natural Gas Delivery Point necessary to maintain the
safety of the Facility consistent with standard gas industry practices.
"PUC" -- New Jersey Department of Public Utilities or any successor
agency thereto.
"RATING AGENCY" -- Standard & Poor's, Xxxxx'x and each other credit
Rating Agency from which Seller seeks to obtain a rating on the debt it
incurs to finance the construction of the Facility.
"REGIONAL TRANSMISSION OWNER (RTO)" -- each entity (a) that owns,
leases or otherwise has a possessory interest in facilities used for the
transmission of electric energy in interstate commerce, (b) that provides
transmission under the PJM Tariff and (c) that is a party to the PJM
Transmission Owners Agreement and PJM Operating Agreement.
"RELIABILITY ASSURANCE AGREEMENT" -- that certain Reliability
Assurance Agreement Among Load Serving Entities in the PJM Control Area,
dated as of June 2, 1997, as amended, revised or superseded from time to
time, including applicable portions of the PJM Manuals.
"REPLACEMENT PRICE" -- has the meaning given such term in Appendix
1, Section V.
"ROLLING TWELVE MONTH PERIOD" -- the most recent twelve months (or
portions thereof) immediately preceding each Billing Month.
"SCHEDULE OR SCHEDULED" -- the act of Xxxxxxxx, Seller, the Host
Utility or Transporter timely notifying, requesting, pre-scheduling,
nominating and confirming to each other, consistent with Transporter's tariff
or procedures or with the Interconnection Agreement and PJM procedures, as
may be applicable, the quantity of Ancillary Services, Net Electric Energy or
Natural Gas to be delivered hereunder in any given hour. As between the
Parties, Xxxxxxxx shall be the exclusive scheduler of any Natural Gas
upstream of the Natural Gas Delivery Point and shall also be the exclusive
scheduler of any Net Electric Energy and Ancillary Services downstream of the
Primary Delivery Point.
"SECOND PAID EXTENSION OPTION" -- has the meaning given such term in
Section 2.2(c).
"SHUTDOWN" -- an actual Shutdown of a Unit, as evidenced by the
opening of the Unit's combustion turbine breaker, or the Facility, as
evidenced by the opening of all of
13
its breakers, immediately following the Ending Requested Dispatch Hour of a
Dispatch Period or pursuant to an Early Shutdown Notice.
"SITE" -- the location of the Facility in Sayreville, New Jersey,
identified as Xxx 0, Xxxxx 49.01 as designated on the Tax Maps of the Borough
of Sayreville.
"STANDARD & POOR'S" -- Standard & Poor's Rating Group, a division of
the XxXxxx-Xxxx Companies, Inc., and its successors.
"START-UP" -- a Start-Up of the Facility, one Unit or two Units
necessary to comply with the Schedule or request by Xxxxxxxx for a Dispatch
Period for the Facility immediately preceding a Beginning Requested Dispatch
Hour.
"START-UP NOTIFICATION LEAD TIME" -- a period of at least [*].
"START-UP TESTING DATE" -- has the meaning given such term in
Section 7.3.
"SUCCESSFUL START-UP" -- a Start-Up that results in the [*],
pursuant to a Xxxxxxxx' Dispatch Notice, for a period of time equal to the
[*], whichever is less.
"SUMMER PEAK PERIOD" -- the months (or portions thereof) of June,
July, August and September.
"TAXES" -- any or all federal, state and/or local, municipal, ad
valorem, property, occupation, severance, generation, first use, conversion,
Btu or power, transmission, utility, gross receipts, privilege, sales, use,
consumption, excise, lease, transaction, and other Taxes, governmental
charges, license fees, permit fees, assessments, or increases in or interest
on or penalties relating to any of the foregoing, other than Taxes based on
net income or net worth.
"TEMPERATURE ADJUSTED FACILITY CAPACITY" -- the capacity of the
Facility to actually generate Net Electric Energy at any particular
temperature measured at the gas turbine inlet between -20 and 100 degrees
Fahrenheit corresponding to the Facility Capacity, and reflecting the effect
of temperature on both the Facility Capacity while in Combined Cycle Mode and
the air/gas flow into the combustion turbine. Seller will provide Xxxxxxxx
with temperature adjusted capacity curves showing expected changes in the
capacity of the Facility at such different temperatures as soon as reasonably
practicable but in no event later than the Commercial Operation Date.
"TEMPERATURE ADJUSTED UNFORCED CAPACITY" OR "TAUC" -- the Unforced
Capacity Rating associated with the Facility adjusted to [*] degrees
Fahrenheit as described in Appendix 9.
14
"TEMPERATURE ADJUSTED UNIT CAPACITY" -- the capacity of any two
Units to generate Net Electric Energy at any particular temperature measured
at the gas turbine inlet between -20 and 100 degrees Fahrenheit corresponding
to approximately 66 percent of Facility Capacity and reflecting the effect of
temperature on both the Unit Capacity while in Combined Cycle Mode and the
air/gas flow into the combustion turbine.
"TERM" -- Subject to Section 16.5 hereof, the Term of this Agreement
commencing on the Execution Date and continuing for a period of twenty (20)
Contract Years after the first Contract Anniversary Date.
"THIRD PARTY ENGINEER" -- has the meaning given such term in Section
11.1.
"XXXXXXXX BANKWATCH" -- Xxxxxxxx Financial Bankwatch, a company that
provides ratings, research and analysis on financial institutions.
"TOTAL FIXED PAYMENT" -- has the meaning given such term in Appendix
1, Section II, A.2.
"TRANSPORTER(S)" -- all Natural Gas gathering or pipeline companies,
or local distribution companies, acting in the capacity of a Transporter,
transporting Natural Gas for Seller or Xxxxxxxx to the Natural Gas Delivery
Point.
"TRANSPORTATION CHARGES" -- those charges associated with the
delivery of Natural Gas from Transco Xxxx 0, Xxx Xxxx, to the Natural Gas
Delivery Point inclusive of fuel. Xxxxxxxx shall provide such charges as soon
as reasonably practicable but in no event later than the Commercial Operation
Date.
"UNFORCED CAPACITY" -- has the meaning given to that term, or any
successor term, in the Reliability Assurance Agreement.
"UNFORCED CAPACITY RATE" -- shall have the meaning given such term
in Appendix 1, Section II, A.2.
"UNFORCED CAPACITY RATING" -- the amount of Unforced Capacity
associated with the Facility for a Billing Month as determined pursuant to
the Reliability Assurance Agreement without regard to whether the Facility is
a "Capacity Resource" pursuant to the Reliability Assurance Agreement.
"UNIT" -- a single independent combined cycle train, consisting of a
combustion turbine and heat recovery steam generator operating together with
associated equipment.
"VARIABLE O&M RATE" OR "VOM" -- a rate applied to each MWh of Net
Electric Energy delivered, as more fully described in Appendix 1, Section II,
A.1.
15
"VARIABLE O&M PAYMENT" OR "VOMP" -- the product of the Variable O&M
Rate and the Net Electric Energy for a Dispatch Period, which is to be paid
by Xxxxxxxx to Seller as set forth in Appendix 1, Section II, A.1.
"WARM START" -- the start of a Unit in Combined Cycle Mode given
that all of the breakers of that Unit's combustion turbine generator have
been open for more than [*] but less than [*] hours.
"WINTER PEAK PERIOD" -- the months (or portions thereof) of
December, January and February.
SECTION 1.2 Interpretation
Unless a different interpretation arises from the context: (a) the
reference to any article, section, paragraph or appendix is a reference to an
article, section, paragraph or appendix of this Agreement, (b) with respect
to the definitions set forth in Article I, whenever applicable the singular
shall include the plural and vice-versa; and (c) the words "includes" or
"including" mean "including, but not limited to" and are not limiting. Any
conflict between an article or section of this Agreement and any provision of
an appendix shall be resolved by reference to the article or section of this
Agreement.
ARTICLE II: TERM
SECTION 2.1 Term
Subject to the terms hereof, including those of Section 16.5, the
Term of this Agreement shall commence on the Execution Date and shall
continue for a period of twenty (20) Contract Years after the first Contract
Anniversary Date.
SECTION 2.2 Commercial Operation Date
(a) Seller shall cause the Commercial Operation Date to occur no
later than December 31, 2001 (the "Anticipated Commercial Operation Date").
If the Commercial Operation Date has not occurred by December 31, 2001, for
any reason whatsoever, including without limitation the continued existence
of, or delay caused by, a Force Majeure event affecting Seller (other than
any delay caused by, an inability of Seller to obtain Natural Gas for the
testing or operation of the Facility, or by any act or failure to act by
Xxxxxxxx or an Affiliate of Xxxxxxxx, where such action is required under
this Agreement), Xxxxxxxx shall (notwithstanding anything in this Agreement
or otherwise to the contrary except this Section 2.2(a)) have the absolute
right to terminate this Agreement upon written notice to Seller without any
liability or responsibility [*].
16
[*]
(b) In the event Seller qualifies for the [*] Option but the
Commercial Operation Date is not achieved by June 30, 2002, (i) Seller may
elect to extend its obligation to achieve the Commercial Operation Date up to
and including June 30, 2003 by paying Xxxxxxxx the amounts, and in accordance
with the procedures, specified in Section 2.2(c) and (ii) Seller shall pay to
Xxxxxxxx an amount equal to the lesser of (x) any actual damages Xxxxxxxx
suffers or incurs after June 30, 2002 as the result of Xxxxxxxx' reliance
upon the delivery by such date of Unforced Capacity, Ancillary Services and
Fuel Conversion Services hereunder, to the extent said damages cannot be
mitigated fully, and (y) [*]. Seller agrees that the damages Xxxxxxxx may
suffer under these circumstances will be any and all reasonable costs
incurred by Xxxxxxxx in excess of costs that would have been incurred had the
Commercial Operation Date occurred on or before December 31, 2001.
(c) In the event Seller qualifies for the [*] Option or elects the
First Paid Extension Option, if the Commercial Operation Date has not
occurred by June 30, 2002, (the "Final CO Date") for any reason whatsoever
(other than as a result of an inability of Seller to obtain Natural Gas for
the testing or operation of the Facility, or any act or failure to act by
Xxxxxxxx or an Affiliate of Xxxxxxxx, where such action is required under
this Agreement), including without limitation the continued existence of or
delay caused by a Force Majeure event affecting Seller, Xxxxxxxx shall
(notwithstanding anything contained in this Agreement or otherwise to the
contrary) have the absolute right to terminate this Agreement upon written
notice to Seller without any liability or responsibility, provided, however,
that notwithstanding the preceding provisions of this sentence, Seller shall
have the right to extend the Final CO Date to and including June 30, 2003 by
giving Xxxxxxxx written notice of the estimated extension required no later
than April 30, 2002 and paying to Xxxxxxxx the amount of [*]/Day for each of
the first 60 Days beyond June 30, 2002, [*]/Day for each Day of delay between
and including 61 and 120 Days after June 30, 2002; and [*]/Day for each Day
of delay between and including 121 and 365 Days after June 30, 2002 (the
"Second Paid Extension Option"). At the end of each month during such
extension period Seller shall calculate the amounts owed to Xxxxxxxx under
the terms of this Section 2.2(c) for such month and shall pay such amounts to
Xxxxxxxx within ten (10) Days after the end of such month.
(d) In the event that Seller elects the Second Paid Extension Option
and the Commercial Operation Date does not occur by June 30, 2003 for any
reason whatsoever (other than as a result of an inability of Seller to obtain
Natural Gas for the testing or operation of the Facility, or any act or
failure to act by Xxxxxxxx or an Affiliate of
17
Xxxxxxxx, where such action is required under this Agreement), including
without limitation the continued existence of or delay caused by a Force
Majeure event affecting Seller, Xxxxxxxx shall (notwithstanding anything
contained in this Agreement or otherwise to the contrary) have the absolute
right to terminate this Agreement upon five (5) Days written notice to Seller
without any liability or responsibility; such right to terminate, however,
shall lapse if not exercised prior to the Commercial Operation Date.
ARTICLE III: PURCHASE OF FUEL CONVERSION SERVICES
SECTION 3.1 Delivery of Natural Gas
Consistent with any Dispatch Notice or as otherwise instructed by
Seller, Xxxxxxxx shall deliver or cause to be delivered to Seller at the
Natural Gas Delivery Point on an exclusive basis all quantities of Natural
Gas required by Seller (i) to generate Net Electric Energy and/or Ancillary
Services, (ii) to perform Start-Ups, (iii) to perform Shutdowns, and (iv) to
operate the Facility during any period other than a Start-Up, Shutdown or
Dispatch Period for any reason. Xxxxxxxx shall at all times retain title to
all quantities of Natural Gas delivered pursuant to clauses (i) -- (iii) of
this Section 3.1, and title to Natural Gas delivered pursuant to clause (iv)
of this Section 3.1 shall transfer to Seller at the Natural Gas Delivery
Point. To the extent of any failure by Xxxxxxxx to deliver the Natural Gas
required pursuant to clauses (i) -- (iii), Seller shall be excused, without
any penalty, from its obligation to provide Fuel Conversion Services and to
deliver the related Net Electric Energy or Ancillary Services under this
Agreement.
SECTION 3.2 Fuel Conversion Services
Subject to the terms and conditions set forth in this Agreement,
during the Term, commencing with the Commercial Operation Date, Seller shall
perform for Xxxxxxxx on an exclusive basis, and Xxxxxxxx shall purchase and
pay for, Fuel Conversion Services.
SECTION 3.3 Fuel Conversion Option Demand Payment
Subject to the terms and conditions set forth in this Agreement,
Xxxxxxxx shall pay Seller a Fuel Conversion Option Demand Payment for Fuel
Conversion Services and Ancillary Services as set forth in Appendix 1,
Section II, A.2.
SECTION 3.4 Costs and Expenses
Except as provided in Section 6.2, Xxxxxxxx shall be solely
responsible for all costs and expenses related to the supply and
transportation of Natural Gas to the Natural Gas Delivery Point.
18
SECTION 3.5 Energy Exercise Fee
Subject to the terms and conditions set forth in this Agreement,
Xxxxxxxx shall pay Seller an Energy Exercise Fee for Net Electric Energy
and/or Ancillary Services received hereunder as set forth in Appendix 1,
Section II, A.3.
SECTION 3.6 Adjustments
Adjustments to the Fuel Conversion Option Demand Payments will be
made pursuant to Xxxxxxxx 0, Xxxxxxx XX,X.
SECTION 3.7 Variable O&M Payments
Subject to the terms and conditions set forth in this Agreement,
Xxxxxxxx shall pay Seller a Variable O&M Payment as set forth in Appendix 1,
Section II, A.1.
SECTION 3.8 Facility Heat Rate Bonus or Credits
Subject to the terms and conditions set forth in this Agreement,
Xxxxxxxx shall pay Seller a Heat Rate bonus or Seller shall provide Xxxxxxxx
a Heat Rate credit pursuant to Appendix 1, Section III.
SECTION 3.9 Alternative Delivery Point
Unless Seller has declared an Emergency, Forced Outage, Maintenance
Outage or Planned Outage, Seller shall deliver the Energy and/or Ancillary
Services to be sold to Xxxxxxxx pursuant to its Dispatch Notice. In the event
Seller has not declared an Emergency, Forced Outage, Maintenance Outage or
Planned Outage and is unable or unwilling to tender delivery at the Primary
Delivery Point, Seller may elect to fulfill its delivery obligations through
one of the following options:
(a) Seller may tender delivery of all or a portion of the Energy and
Ancillary Services pursuant to a Dispatch Notice to an Alternative Delivery
Point subject to the following:
(i) Seller must notify Xxxxxxxx it intends to deliver Energy
and/or Ancillary Services at an Alternative Delivery Point and Xxxxxxxx
must respond to such notice of an Alternative Delivery Point at least
two (2) hours after said notice is received indicating if it will
accept delivery at the Alternative Delivery Point;
(ii) Seller may not elect to deliver Energy and/or Ancillary
Services to an Alternative Delivery Point during any Dispatch Period in
which Seller has already begun delivery of Energy and/or Ancillary
Services to the Primary Delivery Point, unless the Parties agree
otherwise;
(iii) Seller agrees to pay Xxxxxxxx the positive difference,
if any, in each hour, of the Locational Marginal Price at the Primary
Delivery Point minus
19
the Locational Marginal Price at the Alternative Delivery Point
multiplied by the quantity of Energy and Ancillary Services requested
pursuant to the Dispatch Notice for each hour that Energy and Ancillary
Services are delivered to the Alternative Delivery Point; and
(iv) [*]
(v) [*]
(vi) Deliveries at the Alternative Delivery Point shall be
settled pursuant to the then existing settlement procedures as commonly
practiced in the PJM market.
(b) Seller may pay Xxxxxxxx a Non-Dispatch Payment as described in
Appendix 1, Section V.
ARTICLE IV: PURCHASE AND SALE OF UNFORCED CAPACITY
SECTION 4.1 Sale of Temperature Adjusted Unforced Capacity
(a) Subject to the terms and conditions set forth in this Agreement,
during the Term, commencing with the Commercial Operation Date, Seller shall
sell and make available to Xxxxxxxx on an exclusive basis, and Xxxxxxxx shall
purchase and pay for, Temperature Adjusted Unforced Capacity.
(b) The payment for Temperature Adjusted Unforced Capacity in a
Billing Month shall be calculated by multiplying the Temperature Adjusted
Unforced Capacity by the applicable Unforced Capacity Rate as set forth in
and subject to the provisions of Appendix 1 to this Agreement.
SECTION 4.2 Additional and Expansion Capacity
(a) In the event that it is demonstrated during Initial Start-Up
Testing, or during a subsequent demonstration of capacity for PJM purposes,
that the Facility Capacity is greater than 764.3 MW [*], this Agreement
and Appendix 1 to this
20
Agreement shall be amended to reflect the sale of such additional capacity to
Xxxxxxxx as mutually agreed to by the Parties.
(b) Seller will not add Expansion Capacity to the Site, except with
the consent of Xxxxxxxx, which may be withheld in Xxxxxxxx' sole and absolute
discretion if such Expansion Capacity would have an adverse effect on the
economic benefit (including cashflow and profit) to be derived by Xxxxxxxx
from the Facility.
ARTICLE V: PROJECT DEVELOPMENT
SECTION 5.1 Progress Reporting
(a) After the date hereof, Seller shall furnish to Xxxxxxxx, for
information purposes only, updated quarterly (on a calendar year basis)
Schedules and status reports showing and describing the progress of the
engineering, permitting, purchasing and construction of the Facility. The
receipt and/or review by Xxxxxxxx of any such Schedules submitted by Seller
shall not be asserted or construed by Seller at any time to be (i) Xxxxxxxx'
endorsement or approval of the Schedules, (ii) Xxxxxxxx' endorsement or
approval of the design of the Facility or its appurtenant equipment, (iii)
Xxxxxxxx' assumption of any responsibility for the Facility or its
appurtenant equipment and/or (iv) any waiver of any obligation of Seller
under this Agreement. The updated Schedules and reports provided by the
Seller pursuant to this Section 5.1 shall include, in reasonably sufficient
detail, explanations of any delays in meeting Scheduled dates for
commencement or completion of any listed item.
(b) Xxxxxxxx shall furnish Seller with updated quarterly (on a
calendar year basis) Schedule reports showing and describing the progress of
the engineering, permitting and construction of the Natural Gas
Interconnection Facilities.
SECTION 5.2 Establishing Facility Capacity
Seller shall provide to Xxxxxxxx not later than ten (10) Days after
the completion of Initial Start-Up Testing, pertinent written data
substantiating the Facility's capability to provide Facility Capacity. Seller
shall provide to Xxxxxxxx no later than thirty (30) Days prior to the
Commercial Operation Date written data based on design calculations depicting
the Facility's Temperature Adjusted Facility Capacity and Temperature
Adjusted Unit Capacity as a function of temperature between -20 and 100
degrees Fahrenheit, to the extent such information is reasonably available
from the Facility engineering, procurement and construction contractor for
such range. Such written data shall be adjusted by the Parties, as necessary,
based upon actual performance of the Facility during normal operations
subsequent to the Commercial Operation Date.
21
SECTION 5.3 Required Permits and Approvals
Seller shall, at its own cost and expense, obtain as and when
required all approvals, permits, licenses and other authorizations from
governmental authorities as may be required for it to construct, operate and
maintain the Facility, the Interconnection Facilities and Protective Gas
Apparatus and to perform its obligations hereunder and, during the Term
hereof, Seller shall obtain all such additional governmental approvals,
permits, licenses and authorizations as may be required with respect to the
Facility as soon as practicable.
SECTION 5.4 Access to Site
(a) Upon reasonable advance notice to Seller, Seller agrees to
provide reasonable access to the Site to Xxxxxxxx and its contractors, for
the purpose of their construction of the Natural Gas Interconnection
Facilities and to take such other action as may be reasonably necessary for
such Natural Gas Interconnection Facilities to be constructed and connected
to the Facility.
(b) While on the Site, Xxxxxxxx shall ensure that its employees and
its contractors comply with all safety rules of Seller and its contractors
and the directions of Seller regarding areas of restricted acceSection
Xxxxxxxx shall notify Seller of and remove, transport and dispose of, in
accordance with Environmental Law, any Hazardous Materials transported or
released onto the Site by Xxxxxxxx and its contractors.
ARTICLE VI: INITIAL START UP TESTING, TESTING AND COMMERCIAL OPERATION
SECTION 6.1 Other Sales of Energy
(a) Beginning on the date of initial delivery of Net Electric Energy
from Seller to Xxxxxxxx and during any period when there is a demonstration
of Facility Capacity during a period other than a Dispatch Period, or during
any other Facility test operation during a period other than a Dispatch
Period, Seller will sell at the Primary Delivery Point any available Net
Electric Energy to Xxxxxxxx [*], unless Xxxxxxxx has declared a Dispatch
Period.
(b) Notwithstanding the foregoing, if, due to the actions of Seller,
Net Electric Energy is made available at the Primary Delivery Point during a
period other than a Dispatch Period without the authorization of PJM, the
Host Utility or FERC, Xxxxxxxx shall be obligated to pay only the lesser of
the Locational Marginal Price or the actual price for such Net Electric
Energy and Seller shall be solely responsible for any fines or penalties
resulting from the unauthorized delivery of such Net Electric Energy at the
Primary Delivery Point.
22
SECTION 6.2 Purchase of Natural Gas
For Facility Testing or any period other than a Dispatch Period,
upon [*] notice from Seller or other amount of time as mutually agreed to by
the Parties, Xxxxxxxx agrees to sell and deliver, or cause to be sold and
delivered, on a firm basis and Seller agrees to purchase and receive at the
Natural Gas Delivery Point on an exclusive basis, solely for consumption at
the Facility, such quantities of Natural Gas as requested by Seller for such
purposes. Seller shall inform Xxxxxxxx if the Natural Gas to be sold and
purchased is to be used for Facility Testing. The price for the above
referenced Natural Gas shall be set forth in Section 6.3 below.
SECTION 6.3 Gas Price
Subject to Section 6.4, during any period mentioned in Section 6.2
above, Seller shall purchase Natural Gas from Xxxxxxxx at the Gas Price. The Gas
Price includes, and Seller is under no obligation to make additional payments
for, all royalties, Taxes, expenses and costs arising from or attributable to
the Natural Gas prior to its delivery at the Natural Gas Delivery Point.
Xxxxxxxx assumes the obligation, if any, to pay proceeds due royalty owners or
any other Persons entitled thereto.
SECTION 6.4 Replacement Index
In the event that GAS DAILY, or its successor, ceases publication or
the Daily Gas Index otherwise becomes unavailable, the Parties shall use good
faith efforts to agree upon a replacement index. If the Parties cannot agree on
a substitute methodology and/or publication by the end of the first month for
which the replacement index could not be determined, then Xxxxxxxx and Seller
shall each prepare a list of three alternative published reference postings of
spot prices for Natural Gas delivered in the same geographic area as the Natural
Gas Delivery Point. Each list shall set forth the highest priority index first.
Each Party shall submit its list to the other within ten (10) days after the end
of the first month for which the Gas Price could not be determined. The first
index appearing on Xxxxxxxx' list that also appears on Seller's list shall
constitute the new replacement index effective as of the date that the Parties
ceased using GAS DAILY'S Daily Gas Index Price.
SECTION 6.5 Notice of Commercial Operation Date
Seller shall provide to Xxxxxxxx (i) written notice, at least thirty
(30) Days in advance, of the expected Commercial Operation Date, and (ii) a copy
of the notice of Commercial Operation within five (5) Days after the Commercial
Operation Date. Xxxxxxxx shall have the right to be present at Initial Start-Up
Testing of the Facility.
SECTION 6.6 Demonstration of Facility Capacity
During Initial Start-Up Testing and thereafter, Seller shall
demonstrate, in accordance with the then-applicable criteria of PJM (or the most
recent such criteria if
23
current PJM criteria no longer exist), applicable generally to independent power
and utility generating facilities in the PJM control area of similar technology,
the capability of the Facility to produce and maintain, as required for such
demonstration, the Facility Capacity. The demonstration of Facility Capacity
shall be Scheduled by Seller and consistent with PJM requirements. Seller shall
be responsible for all costs, including transmission costs, it incurs in
connection with the demonstration of Facility Capacity; and Seller shall have
the obligation to obtain or maintain any transmission service beyond the Primary
Delivery Point that may be required for such demonstration of Facility Capacity
prior to the Commercial Operation Date. Seller shall not have the obligation to
secure transmission service after the Commercial Operation Date to sell such
Facility Capacity.
ARTICLE VII: INTERCONNECTION AND METERING EQUIPMENT
SECTION 7.1 Responsibility for Interconnection Facilities
At its sole cost and expense, Seller shall own, design, construct,
install and maintain, or be responsible for the design, construction,
installation and maintenance of the Facility, the Interconnection Facilities and
Protective Gas Apparatus needed to generate and deliver Net Electric Energy and
Ancillary Services to the Primary Delivery Point in order to fulfill its
obligations as specified herein, including all Interconnection Facilities and
Protective Gas Apparatus that may be located at any switchyard and/or substation
to be built at the Facility. Not later than ninety (90) Days after the Execution
Date, Seller shall prepare and submit to Xxxxxxxx a preliminary one-line
interconnection diagram depicting the Primary Delivery Point, which diagram
shall be incorporated by reference herein as Appendix 4.B. The Facility,
Interconnection Facilities and Protective Gas Apparatus shall be designed,
constructed and completed in a good and workmanlike manner and in accordance
with Accepted Electrical Practices (with respect to the Facility and
Interconnection Facilities) or in accordance with standard gas industry
practices (with respect to Protective Gas Apparatus), such that the expected
useful life of the Facility, the Interconnection Facilities and Protective Gas
Apparatus shall be not less than the Term of this Agreement.
SECTION 7.2 Amendment of Interconnection Agreement
(a) Seller shall not enter into any modification or amendment of the
Interconnection Agreement with Host Utility, or any successor entity thereto,
without the prior written consent of Xxxxxxxx (such consent not to be
unreasonably withheld) unless such modification or amendment is required to
comply with the Host Utility's or PJM's requirements and procedures or Accepted
Electric Practices.
(b) Should the Host Utility, or any successor entity thereto, notify
Seller of Host Utility's intent to unilaterally modify or amend the
Interconnection Agreement, Seller shall provide to Xxxxxxxx written notice of
the aforementioned modification or
24
amendment within [*] after Seller's receipt of such notice from Host Utility.
SECTION 7.3 Gas Interconnection
(a) Xxxxxxxx shall be responsible for the construction of all Natural
Gas Interconnection Facilities necessary for delivery of Natural Gas up to and
including the Natural Gas Delivery Point (including the Natural Gas Metering
Equipment but excluding compressors ("Natural Gas Interconnection Facilities"))
and shall use all commercially reasonable efforts to expeditiously construct or
contract for the expeditious construction of such Natural Gas Interconnection
Facilities in order to make Natural Gas available to Seller at the Natural Gas
Delivery Point no later than [*] prior to the Anticipated
Commercial Operation Date. In the event that such Natural Gas Interconnection
Facilities have not been constructed and/or Xxxxxxxx is unable for any reason to
deliver Natural Gas to the Facility by the date that the Facility would
otherwise be prepared to begin Initial Start-Up Testing, but in no event prior
to the date Scheduled therefor, (the "Start-Up Testing Date"), and but for the
failure to provide such Natural Gas the Facility is otherwise ready, or would
otherwise have been ready, to begin such testing (as reasonably determined by a
Third Party Engineer chosen in accordance with the provisions of this
Agreement), then [*].
(b) Seller shall ensure that sufficient area is preserved at the Site
to allow for the construction of all Natural Gas Interconnection Facilities.
Such area shall not exceed 150 feet by 100 feet in dimension.
(c) Upon the expiration of this Agreement or any termination of this
Agreement as the result of a Xxxxxxxx' event of default thereunder, Seller
shall have the right to purchase the Natural Gas Interconnection Facilities
from Xxxxxxxx, free and clear of all liens, other than Permitted Liens, and
encumbrances, for an amount [*] Natural Gas Interconnection Facilities, or in
the event that Xxxxxxxx does not own such Natural Gas Interconnection
Facilities, Xxxxxxxx shall assign to Seller all of its rights to
transportation services using such Natural Gas Interconnection Facilities,
free and clear of any obligations of Xxxxxxxx to the transportation services
provider incurred or arising prior to the date of such assignment.
25
ARTICLE VIII: OPERATION AND DISPATCH
SECTION 8.1 Operation Standards
The Facility and the Interconnection Facilities shall be operated in
accordance with Accepted Electrical Practices and the applicable requirements
and guidelines of the Host Utility pursuant to the Interconnection Agreement.
The Protective Gas Apparatus shall be operated in accordance with standard gas
industry practices. In the event of a conflict between the terms and conditions
of this Agreement and Host Utility requirements, the Host Utility requirements
shall control.
SECTION 8.2 Parallel Operation
Seller shall operate the Facility in parallel with the Host Utility's
electrical system pursuant to the Interconnection Agreement.
SECTION 8.3 Disconnection by Host Utility
(a) Notwithstanding anything contained in this Agreement to the
contrary, the Parties acknowledge that under the Interconnection Agreement the
Host Utility shall have the right to require Seller to disconnect the Facility
from the Host Utility's electrical system (or otherwise curtail, interrupt,
reduce or modify deliveries of Net Electric Energy and Ancillary Services) in
accordance with the terms of the Interconnection Agreement. When the Host
Utility disconnects the Facility in accordance with the terms of the
Interconnection Agreement, Xxxxxxxx shall not be responsible for any costs
incurred by Seller due to such disconnection. Notwithstanding any other
provision of this Agreement to the contrary, [*]
26
[*]
(b) Seller shall use commercially reasonable efforts to correct
promptly any condition at the Facility which necessitates the disconnection of
the Facility from the Host Utility's electrical system or the reduction,
curtailment or interruption of electrical output of the Facility.
(c) Seller shall notify Xxxxxxxx as soon as reasonably practicable of
receipt by Seller of a notice from the Host Utility of Host Utility's intent to
disconnect the Facility from the Host Utility's electrical system or otherwise
curtail, interrupt, reduce or modify deliveries of Net Electric Energy and
Ancillary Services.
SECTION 8.4 Automatic Regulation
(a) When Dispatched by Xxxxxxxx, Seller shall operate the Facility and
each Unit with Automatic Regulation equipment in service.
(b) Seller shall provide to Xxxxxxxx response rates greater than the 5
MW/minute minimum criteria for Automatic Regulation, when such faster response
rates are within the equipment supplier's operating guidelines and the Facility
control systems are technically sufficient for such faster response rates.
SECTION 8.5 Energy and Ancillary Nominations and Confirmations
Prior to the date and time of flow at the Primary Delivery Point, the
Parties shall Schedule Net Electric Energy and/or Ancillary Services which will
be delivered or received. Such confirmation between the Parties shall be made
verbally, unless otherwise mutually agreed to by the Parties.
SECTION 8.6 Right to Energy and Ancillary Services
(a) Xxxxxxxx shall at all times have the exclusive right to utilize the
Net Electric Energy and Ancillary Services associated with the Temperature
Adjusted Facility Capacity, subject to the terms and conditions specified herein
and the obligations of the Parties under the PJM Agreement.
(b) Xxxxxxxx shall have the exclusive right to Schedule the Contract
Quantity pursuant to a Dispatch Notice issued in accordance with the provisions
of this Agreement; provided, however, that such Scheduling also shall be
consistent with the design and operating limitations of the Facility, applicable
law, regulations and permits, and the obligations of the Parties under the PJM
Agreements and the PJM Manuals.
(c) If there is a difference in the Locational Marginal Price between
the two delivery buses that comprise the Primary Delivery Point, Xxxxxxxx may
request a partial Dispatch of the Facility on a per bus basis. Seller shall use
its good faith efforts,
27
consistent with design and operating limitations of the Facility and the
Interconnection Facilities and Accepted Electrical Practices, to comply with
such a Dispatch Notice. Seller shall advise Xxxxxxxx' of its ability to comply
with such request within fifteen (15) minutes of its receipt and promptly notify
Xxxxxxxx of any change in its ability to comply with such request during the
Dispatch Period. [*]
(d) Xxxxxxxx, in the absence of an Emergency, shall not Schedule a
Dispatch Period of less than [*] hours unless the Facility was operated (or
was requested to so operate) within the [*] hours prior to the requested
Dispatch Period.
(e) When a Dispatch Period will involve a Start-Up, Xxxxxxxx shall
provide Seller, in the absence of an Emergency, with at least the advance notice
of a Dispatch Period consistent with the Start-Up Notification Lead Time and
such Dispatch Period shall begin after the applicable Allocated Start-Up
Duration. When a Dispatch Period, including revisions to a previously Scheduled
Dispatch Period, does not involve a Start-Up, Xxxxxxxx, in the absence of an
Emergency, shall provide Seller, with at least [*] minutes advance
notice of such Dispatch Period or revised Dispatch Period.
SECTION 8.7 Facility Availability Status
(a) Seller shall no later than [*] minutes after Seller's
receipt of a Dispatch Notice notify Xxxxxxxx of (i) the Facility's expected
availability during the Dispatch Period identified in such Dispatch Notice and
(ii) if the Facility is to be available, the expected volume of Natural Gas
required to comply with the Dispatch Notice. To the extent Seller does not
notify Xxxxxxxx within such [*] minute period, the Facility shall be
deemed Fully Available.
(b) When a Dispatch Period has been requested by Xxxxxxxx and accepted
by Seller, Seller shall have until the end of the Allocated Start-Up Duration to
produce the requested output level.
(c) If, at the end of the Allocated Start-Up Duration, the Facility is
unable to produce the requested output level or if Seller notifies Xxxxxxxx
pursuant to Section 8.7(a) above that the Facility or any portion thereof is
unavailable, the Facility shall then be considered to be in a Total or Partial
Forced Outage. The Facility will remain in this status until such time as
Xxxxxxxx is notified by the Seller that the Facility is again Fully Available
for Dispatch and, at Xxxxxxxx' option can demonstrate this availability over a
two hour period. At the end of the fully or partially successful demonstration,
the Facility will be considered to be Fully or Partially Available,
respectively. If, however, Xxxxxxxx elects not to dispatch the Facility when
Seller
28
notifies Xxxxxxxx of the Facility's availability, then Seller may choose to
demonstrate Facility Availability as specified above, subject to the Seller
being responsible for any costs, providing however, that the Host Utility is
able to accept the energy produced. If Seller chooses not to test or if the Host
Utility, in its sole judgment, would not be able to accept the Energy produced
during such a demonstration, then Xxxxxxxx shall recognize the Facility as being
available; provided, however, that if the Facility is unavailable at the next
Scheduled Dispatch Period request, the Facility will then be considered to be
continuously unavailable from the time of the original request.
SECTION 8.8 Combined Cycle Operation
Xxxxxxxx shall have no right to require operation of the Facility
except in Combined Cycle Mode, unless otherwise mutually agreed to by the
Parties.
SECTION 8.9 O&M Contractor
In the event Seller or an Affiliate of Seller does not directly operate
the Facility, Seller shall, prior to the Commercial Operation Date, enter into,
and during the Term hereof shall maintain in effect, an agreement with a
reputable firm or firms providing for the operation and maintenance of the
Facility pursuant to the terms and conditions of this Agreement at all times
during the Term of this Agreement. The choice of such firm by Seller shall be
subject to the prior review and acceptance by Xxxxxxxx, which acceptance shall
not be unreasonably withheld or delayed; provided that it shall not be
unreasonable for Xxxxxxxx to withhold such acceptance if such operator is a FERC
authorized power marketer or an Affiliate of such an entity. Seller shall
provide Xxxxxxxx with a copy of such agreement and all amendments and
supplements thereto promptly after execution thereof.
SECTION 8.10 Delivery to Facility
Seller shall be responsible for all costs and expenses related to the
transportation, gathering or Taxes of Natural Gas or its use or possession at
and after the Natural Gas Delivery Point to the Facility.
SECTION 8.11 Natural Gas Nominations and Scheduling
Xxxxxxxx shall be solely responsible for scheduling the Natural Gas
that will be delivered to the Natural Gas Delivery Point pursuant to Section
3.1.
SECTION 8.12 Imbalance Prevention
The Parties intend that the quantity of Natural Gas actually delivered
and received each hour will, as nearly as practicable, equal the Scheduled
quantity. Any Imbalance created, when the actual physical flow is different than
the Scheduled quantity, will be the "Imbalance", which will be the
responsibility of the Parties to use commercially reasonable efforts to
eliminate. Estimated quantities flowing at the Natural Gas Delivery
29
Point shall be used on an hourly basis during any delivery period to determine
the estimated Imbalance. Physical flow adjustments are to be made during that
delivery period as mutually agreed to by both Parties to attempt to maintain or
achieve an Imbalance of zero at the Natural Gas Delivery Point. During a
Dispatch Period, Seller shall notify Xxxxxxxx promptly of any change in the
operation of the Facility that will increase or decrease the expected levels of
Natural Gas that will be consumed.
SECTION 8.13 Transporter Penalties
Each Party shall perform its obligations under this Agreement so as to
avoid the creation of penalties, cashout obligations or other similar charges
imposed by the Transporter. Each Party shall promptly notify the other whenever
either has knowledge of an actual or potential Imbalance condition that must be
corrected to avoid the creation of Imbalance penalties or cashout obligations of
the Transporter. Each Party shall also comply with any curtailment or allocation
requirements of the Transporter provided timely notice of such requirements has
been given. Seller shall be responsible for any penalties, cashout obligations
or other similar charges caused by Seller. Xxxxxxxx shall be liable for all
other penalties, cashout obligations or other similar charges.
SECTION 8.14 Actual Flow of Natural Gas
(a) The actual measured quantity of Natural Gas at the Natural Gas
Delivery Point each month shall be determined and communicated by the monthly
statement of the Transporter at the Natural Gas Delivery Point. The actual
measured quantity shall be determined pursuant to the applicable provisions of
the Transporter's tariff or applicable measurement procedures. Imbalances shall
be calculated by using Transporter's monthly statements.
(b) Xxxxxxxx shall, consistent with the terms of Transporter's tariff,
mitigate any Imbalances to minimize any Imbalance charge under such tariff.
Seller shall be responsible for an Imbalance charge under the Transporter's
tariff only to the extent any Imbalance remaining after Xxxxxxxx efforts to
mitigate such Imbalance is attributable to either (i) a difference caused by
Seller greater than the allocable tolerance in the Transporter's tariff or
balancing requirements between the volumes of Natural Gas actually consumed and
the levels identified by Seller pursuant to Section 8.7 or (ii) a failure of
Seller to promptly notify Xxxxxxxx of a change in the operation of the Facility
pursuant to Section 8.12. [*]
ARTICLE IX: MAINTENANCE
SECTION 9.1 Maintenance Standards
(a) At all times during the Term of this Agreement, Seller shall, at
its sole cost and expense, maintain the Facility and the Interconnection
Facilities in accordance with
30
Accepted Electrical Practices, the requirements of the Interconnection Agreement
and engineering, procurement and construction contractors' recommended
maintenance procedures.
(b) At all times during the Term of this Agreement, Seller shall, at
its sole cost and expense, maintain the Protective Gas Apparatus in accordance
with standard gas industry practice and engineering, procurement and
construction contractors' recommended maintenance procedures.
(c) Seller shall have full and complete responsibility for and control
over maintenance of the Facility, the Interconnection Facilities and Protective
Gas Apparatus except for the Parties' rights to test Electric Metering
Equipment.
SECTION 9.2 Maintenance Certification
Seller shall furnish to Xxxxxxxx, in writing, by no later than each
February 15 following the Commercial Operation Date, a certificate together with
supporting documentation demonstrating that Seller has performed or caused to be
performed during the prior year all (i) engineering, procurement and
construction contractor-recommended maintenance and testing of the
Interconnection Facilities and Protective Gas Apparatus and (ii) maintenance of
the Facility necessary to conform with Accepted Electrical Practices. Seller
shall provide Xxxxxxxx with at least thirty (30) Days prior written notice of
any test of the Interconnection Facilities and Protective Gas Apparatus and, to
the extent consistent with the terms of the Interconnection Agreement, Xxxxxxxx
personnel or its representatives may observe such testing.
SECTION 9.3 Records of Outage Statistics
Seller shall maintain and classify outage statistics for the Facility
in accordance with outage classification procedures adopted by PJM and shall
supply such statistics to Xxxxxxxx upon Xxxxxxxx' reasonable request.
SECTION 9.4 Operations Forecasts
(a) Xxxxxxxx shall furnish to Seller by the date which is [*] months
prior to the Anticipated Commercial Operation Date and by [*] of each year
following the Commercial Operation Date a forecast of the Dispatch of the
Facility for the following [*] in order to provide Seller with planning
information to support Seller's scheduling of Planned Outages. Xxxxxxxx shall
provide updates to the forecast in a timely manner if Xxxxxxxx' expectations
of Facility Dispatch are revised.
(b) Seller shall furnish Xxxxxxxx with an annual forecast no later
than [*] of each year, or such other time as may be necessary to be
consistent with regional reliability planning procedures, setting forth the
expected dates and anticipated duration of each Planned Outage for the
succeeding [*]. Subject to the
31
requirements of the PJM Agreement, Reliability Assurance Agreement and PJM
Tariff, Seller and Xxxxxxxx shall mutually agree on the scheduling of all
Planned Outages, but in no event should the Planned Outages be Scheduled during
Summer Peak Periods or Winter Peak Periods. Any requested revision to a Schedule
for a previously approved Planned Outage or a need for a Planned Outage which
arises after a submission of the most recent annual forecast shall be submitted
by either Party to the other as soon as reasonably practicable, but in no event
less than [*] months in advance of the Planned Outage, provided however,
that the [*] month advance notice requirement for the request shall be
waived if the Facility becomes unavailable due to a Force Majeure event within
the [*] months immediately preceding the Planned Outage. The non-requesting
Party shall approve or reject said request within [*] Days of its receipt
and, if it rejects said request shall propose an alternate Schedule with dates
as close in time as practicable to the dates originally proposed. Except as set
forth in the last sentence of this Section 9.4(b), neither Party shall
unreasonably withhold or delay its approval of any requested revision(s) to the
previously established Planned Outage Schedule. Any reasonable costs associated
with a change requested by Xxxxxxxx to the previously established Planned Outage
Schedule shall be agreed to and allocated by the Parties at the time of Seller's
consideration of Xxxxxxxx' requested change. Planned major maintenance shall
normally be Scheduled as a Planned Outage. Xxxxxxxx shall have no right to
require Seller to change the time of a previously Scheduled Planned Outage if,
in the reasonable judgment of Seller, said change is imminently likely to cause
significant physical damage to the Facility or appurtenant equipment.
(c) Seller shall notify Xxxxxxxx as soon as practicable of Seller's
intent to remove the Facility from service for maintenance and its intent to
return the Facility to service following the completion of maintenance. Seller
shall coordinate the scheduling of all Maintenance Outages with Xxxxxxxx.
(d) Seller shall also notify Xxxxxxxx as soon as possible concerning
the cause and anticipated duration of any Maintenance Outage or Forced Outage.
ARTICLE X: METERING, BILLING, PAYMENT AND TAXES
SECTION 10.1 Generally
All Electric Metering Equipment and Natural Gas Metering Equipment
whether owned by Seller, Xxxxxxxx or by a third party, shall be operated,
maintained and tested in accordance with Accepted Electrical Practices, in the
case of the Electric Metering Equipment, and in accordance with applicable
industry standards, in the case of the Natural Gas Metering Equipment.
SECTION 10.2 Metering of Net Electric Energy
Net Electric Energy delivered by Seller to Xxxxxxxx shall be metered at
the Primary Delivery Point, using the Host Utility's Electric Metering Equipment
on an hour-
32
by-hour basis, or such shorter intervals as may be necessary to implement this
Agreement, as are technically feasible using such metering equipment and are
agreed to by the Host Utility. It is the assumption of the Parties that the Host
Utility will agree to own the electric meters at the Primary Delivery Point and
to provide the necessary metering services. In the event the Host Utility elects
not to do so, the Parties will amend this Agreement to reflect that Xxxxxxxx
shall own the electric meters at the Primary Delivery Point and shall provide
the necessary metering services, provided, however, that Seller shall have the
right to install check meters for auditing purposes. Seller shall use reasonable
efforts to ensure that Xxxxxxxx shall have the right to receive data in
electronic form in real time on a continuous basis from the Host Utility's
Electric Meter Equipment; provided, however, that Xxxxxxxx shall be responsible
for any incremental costs incurred to provide such real time information.
SECTION 10.3 Metering of Natural Gas
Xxxxxxxx at its sole cost and expense shall inspect and calibrate, or
cause to be inspected and calibrated, all Natural Gas Metering Equipment
periodically, but not less frequently than annually. In addition, either Party
from time to time with reasonable advance notice to the other Party may request
that the Natural Gas Metering Equipment be tested. When any test shall show a
measurement error of more than two percent (2%) or such lower percentage as may
be established by applicable tariff, correction shall be made for the period
during which the measurement instruments were in error, first, by using the
registration of Seller's check meter, if installed and registering accurately;
if no check meter is installed and registering accurately, or if the period
cannot be ascertained, correction shall be made for one-half (1/2) of the period
elapsed since the date of the last test of such meter; and such meter shall be
adjusted immediately to measure accurately. In the event that any test requested
by a Party pursuant to the second sentence of this Section 10.3 shows a
measurement error as set forth above, the owner of the tested equipment shall
pay for such test and calibration. In the event that no such error is shown, the
Party requesting such test shall pay for such test.
SECTION 10.4 Monthly Statements
(a) Seller shall provide to Xxxxxxxx a monthly statement, included
herein as Appendix 8, using the Host Utility's meters and statements, or Back-Up
Electric Metering Equipment installed by Seller in the event that the Host
Utility's electric meters are not functional, not later than thirty (30)
calendar Days after the end of each Billing Month, unless such thirtieth (30th)
Day is not a Business Day. If such thirtieth (30th) Day is not a Business Day,
Seller shall provide the statement on the next succeeding Business Day. Such
statement shall set forth the amount of Net Electric Energy and Ancillary
Services delivered by Seller to Xxxxxxxx in each hour and Seller's computation
of the amount due from Xxxxxxxx to Seller and such other amounts as may then be
due and payable by Xxxxxxxx to Seller hereunder. Xxxxxxxx shall pay Seller the
net amount shown to be due to Seller on the monthly statement by wire transfer
to an account specified by Seller not later than ten (10) calendar Days
following Xxxxxxxx' receipt of the monthly statement, unless such tenth (10th)
Day is not a Business Day. If such monthly statement shall reflect a net amount
due to Xxxxxxxx from Seller, Seller shall make payment of the net amount shown
to be due to Xxxxxxxx in the monthly statement by wire transfer to an account
specified by Xxxxxxxx not later than ten (10) calendar Days following Xxxxxxxx
receipt of the
33
monthly statement, unless such tenth (10th) Day is not a Business Day. If such
tenth (10th) Day is not a Business Day, Xxxxxxxx or Seller, whichever the case
may be, shall render payment on the next Business Day. All said payments shall
be deemed to be made when such wire transfer is received by Seller or Xxxxxxxx.
Overdue payments shall accrue interest from, and including, the due date to, but
excluding, the date of payment at the Late Payment Interest Rate. If either
Party, in good faith, disputes a monthly statement, such Party shall provide to
the other Party a written explanation of the basis for the dispute and shall
make payment of the portion of such monthly statement not disputed no later than
the due date. To the extent any disputed amount is later determined to be
properly due and payable, it shall be paid within ten (10) Days of such
determination, together with interest accrued at the Late Payment Interest Rate
from the due date to the date payment is made, if made within ten (10) Days of
such determination, and if not paid within ten (10) Days of such determination,
together with interest accrued after such ten (10) Days period to the date
payment is made at the Late Payment Interest Rate plus one (1) percent per
annum. If a Party does not receive written notice of an objection by the other
Party to a monthly statement within ninety (90) days of receipt thereof by such
Party, such monthly statement shall be deemed conclusive and binding absent
manifest error.
(b) Xxxxxxxx shall supply Seller with a monthly invoice for Natural Gas
consumed during any period other than a Dispatch Period. Xxxxxxxx shall
additionally supply Seller with a monthly statement reflecting the actual
quantities of Natural Gas delivered to the Natural Gas Delivery Point.
(c) In the event adjustments or corrections to monthly statements are
required as a result of inaccurate Electric Metering Equipment or Natural Gas
Metering Equipment or other errors in computation or billing, the Parties shall
promptly recompute amounts due from or to each other hereunder during the period
of inaccuracy and otherwise correct any errors in such monthly statement. If the
total amount, as recomputed, due from a Party for the period of inaccuracy
varies from the total amount due as previously computed, and the payment of the
previously computed amount has been made, the difference shall be paid to the
Party entitled to it within ten (10) Days after correction of the erroneous
invoice(s), together with interest on such difference from, and including, the
date on which previously paid to, but excluding, the date the difference shall
be paid to the Party entitled to it at the Late Payment Interest Rate.
(d) Each Party has the right, at its sole expense, upon reasonable
notice and during normal working hours, to examine and copy the records of the
other Party to the extent reasonably necessary to verify the accuracy of any
statement, charge or computation made pursuant to this Agreement. If requested,
a Party shall provide to the other Party statements evidencing the amounts of
Net Electric Energy delivered at the
34
Primary Delivery Point. If any such examination reveals any inaccuracy in any
statement, the necessary adjustments in such statement and the payments thereof
will be promptly made and shall bear interest calculated at the Late Payment
Interest Rate from the date the overpayment or underpayment was made until paid;
provided, however, that no adjustment for any statement or payment will be made
unless objection to the accuracy thereof was made prior to the lapse of two
years from the rendition thereof; and provided further that this Section 10.2(c)
will survive any termination of the Agreement for a period of two (2) years from
the date of such termination for the purpose of such statement and payment
objections.
(e) Seller shall give reasonable notice to Xxxxxxxx of the time when
any Electric Metering Equipment test or Back-Up Electric Metering Equipment test
shall take place, and Xxxxxxxx may have representatives present during such
test(s). To the extent practicable, Seller shall provide at least forty-eight
(48) hours notice to Xxxxxxxx prior to any test it or the Host Utility may
perform on any Electric Metering Equipment or Back-Up Electric Metering
Equipment. In any case, Seller shall provide Xxxxxxxx with a copy of the test
data and results.
(f) If the Electric Metering Equipment fails to register, or if the
measurement made by said meter during a test varies by more than one percent
(1%) (i.e., varies by more than one percent (1%) either above or below the
measurement made by the standard meter used in the test), an adjustment in
payments to Seller or credits to Xxxxxxxx shall be made utilizing the Back-Up
Electric Metering Equipment provided it meets the 1% accuracy requirement stated
above, for the actual period during which inaccurate measurements were made if
the period can be reasonably determined or, if the period of the inaccuracy
cannot be reasonably determined, for no more than one-half the period since the
last meter test.
(g) If, at any time, both the primary and Back-Up Electric Metering
Equipment fail to register, or the registration thereof becomes so erratic as to
be meaningless (i.e., the recording of the measurement is obviously in error),
the Net Electric Energy delivered to Xxxxxxxx shall be determined from the best
information available, including, but not limited to, Seller's additional
electric meters and operator's logs.
SECTION 10.5 Record Retention
Seller shall, for a period of two (2) years, keep and maintain accurate
and complete records for the Facility in a manner consistent with Accepted
Electrical Practice, applicable statutes, codes, regulations, standards and
guidelines adopted by governmental authorities, from time to time, including
such information relating to the operation and maintenance of the Facility and
all associated equipment as is appropriate. Seller shall make such records
available to Xxxxxxxx for inspection from time to time as Xxxxxxxx may
reasonably request. If Seller shall propose to discard any records theretofore
required to be retained by this Article X it shall give Notice thereof to
35
Xxxxxxxx, and Xxxxxxxx may within thirty (30) Days elect to take possession of
such records by Notice to Seller; in such case Seller shall promptly deliver
such records to Xxxxxxxx at Xxxxxxxx' expense. If Xxxxxxxx does not respond
within thirty (30) Days, Seller may discard such records without any further
obligation hereunder.
SECTION 10.6 Maintenance and Testing of Gas Metering Equipment
(a) Seller shall cooperate in the maintenance and testing of all Gas
Metering Equipment owned by Xxxxxxxx or third parties as may be required to
implement this Agreement. All Gas Metering Equipment owned by Seller used to
support billing under this Agreement shall be operated, maintained and tested by
and/or on behalf of Seller in accordance with applicable industry standards and
Transporter's Tariff. If, at any time, any Gas Metering Equipment is out of
service or fails to register, or the registration thereof becomes manifestly
erroneous, the quantity of Natural Gas delivered to the Facility shall be
determined:
(i) by using the registration of any check meter(s) if
installed and accurately registering or, in the absence of said check
meter(s),
(ii) by correcting the error or the percentage of error if
ascertainable by calibration, test or mathematical calculation or, in
the absence of this subparagraph and subparagraph (i) above,
(iii) by estimating the quantity of receipts and deliveries
during periods under similar conditions when the meter was registering
accurately.
(b) Each Party shall have the right to be present at the time of
installing, reading, cleaning, changing, repairing, inspecting, testing,
calibrating or adjusting performed in connection with Gas Metering Equipment
involved in billing and used in measuring or checking the measurement of
receipts and deliveries, including any Gas Metering Equipment involving the
accurate measurement of the Natural Gas delivered to the Facility.
SECTION 10.7 Responsibility for Taxes
(a) The payments by Xxxxxxxx to Seller do not include reimbursement
for, and Xxxxxxxx is liable for and shall pay, cause to be paid, or reimburse
Seller if Seller has paid, all Taxes imposed on or with respect to Natural Gas
or the use or consumption or transportation thereof (other than any of such
Taxes for which Seller is liable under Section 10.7(b)) or on Net Electric
Energy and Ancillary Services or the use and consumption thereof after the
Primary Delivery Point. Xxxxxxxx shall indemnify, defend and hold harmless
Seller from any liability for such Taxes.
(b) The payments by Xxxxxxxx to Seller include full reimbursement for,
and Seller shall be liable for and shall pay, or cause to be paid, or reimburse
Xxxxxxxx if Xxxxxxxx has paid, all Taxes, except as provided in Sections 10.7(a)
or 10.7(d), applicable
36
to the sale to Xxxxxxxx of Net Electric Energy, Unforced Capacity and Ancillary
Services, payments made to Seller in respect of the performance of Fuel
Conversion Services or otherwise relating to or arising out of this Agreement or
the transactions contemplated hereby, including all Taxes imposed on or with
respect to the Facilities, the operation or control thereof, and the associated
electric energy and Natural Gas to which Seller takes title pursuant to Section
3.1(iv) therewith. If Xxxxxxxx is required to remit any Tax for which Seller is
responsible, the amount shall be deducted from any sums due to Seller. Seller
shall indemnify, defend and hold harmless Xxxxxxxx from any liability for such
Taxes.
(c) Either Party, upon written request of the other, shall provide a
certificate of exemption or other reasonably satisfactory evidence of exemption
if either Party is exempt from any Taxes, and shall use all reasonable efforts
to obtain or maintain, or to enable the other Party to obtain or maintain, any
exemption from or reduction of any Tax, whether currently available or becoming
available in the future. Without limiting the generality of the foregoing, the
Parties agree that, if beneficial to the efforts of either Party to obtain or
maintain any exemption from or reduction of any Tax, whether currently available
or becoming available in the future, the Parties will cooperate to restructure
the transactions contemplated by this Agreement so as to enable either Party to
obtain or maintain such exemption or reduction, as the case may be; provided,
however, that any such restructuring shall not affect adversely the economic
interests of either Party under this Agreement.
(d) (i) Notwithstanding any other provision of this Agreement to the
contrary, if (A) a New Tax is imposed and Xxxxxxxx or Seller would be
responsible for such New Tax and (B) such New Tax is (x) imposed on or
applicable to the transactions contemplated by this Agreement,
including without limitation, the sale of Unforced Capacity or the
performance of Fuel Conversion Services, and not imposed on and
generally applicable to the sale of capacity or the use of Natural Gas
to generate electricity or to provide Fuel Conversion Services in the
State of New Jersey, Seller shall pay or cause to be paid, or reimburse
Xxxxxxxx if Xxxxxxxx shall have paid, all such New Taxes and Seller
shall indemnify, defend and hold harmless Xxxxxxxx from any liability
for such New Taxes, or (y) imposed on and generally applicable to the
sale of capacity or the use of Natural Gas to generate electricity or
to provide Fuel Conversion Services in the State of New Jersey, then
Xxxxxxxx shall pay or cause to be paid, or reimburse Seller if Seller
shall have paid, all such New Taxes and Xxxxxxxx shall indemnify,
defend and hold harmless Seller from any liability for such New Taxes.
(ii) If a New Tax is imposed and the Parties shall disagree as
to whether such New Tax is described in Section 10.7(d)(i)(B)(x), on
the one hand, or Section 10.7(d)(i)(B)(y), on the other, or if such New
Tax is not described in either such clause, the characterization of
such New Tax under Section 10.8(d)(i)(B)(x) or Section 10.7(d)(i)(B)(y)
or the allocation of responsibility for
such New Tax to one of; or between, the Parties shall be determined
pursuant to Section 11.2. The arbitrators selected pursuant to such
section, in selecting the proposal most fairly resolving the Parties'
disagreement, shall do so by selecting the proposal most fairly
resolving the question consistent with the principles of this Section
10.7.
SECTION 10.8 Fuel Conversion Volume Rebate and Non-Dispatch Payments
(a) Xxxxxxxx shall be entitled (i) to a Fuel Conversion Volume
Rebate ("FCVR"), calculated by Seller in accordance with Appendix 1, Section
II.B to this Agreement, and (ii) Non-Dispatch Payments, to the extent such
payments are due, as defined in and calculated by Seller in accordance with
Appendix 1, Section V to this Agreement. [*]. FCVR payments and Non-Dispatch
Payments shall be paid to Xxxxxxxx within twenty (20) Days after the date
payments are to be made to Lenders in accordance with Seller's financing
documents for the FCVR payments and Non-Dispatch Payments earned prior to
those payments to Lenders but not yet paid to Xxxxxxxx hereunder. Seller
shall use reasonable efforts to arrange payments to the Lenders on a
quarterly basis. FCVR payments and any Non-Dispatch Payments owed to Xxxxxxxx
and not paid when due shall be paid, together with interest thereon at the
Late Payment Interest Rate, immediately when funds become available to Seller
and prior to any distribution to holders of equity interests in Seller.
Seller represents and warrants that its financing documents will contain
provisions that give effect to the foregoing provisions, and Seller covenants
that none of such provisions in its financing documents will be amended,
modified, waived or terminated without the prior written consent of Xxxxxxxx.
(b) Seller represents and warrants that its financing documents will
require Seller to maintain a separate account (the "Major Maintenance Reserve
Account") with a trustee for its Lenders into which Seller must deposit on a
monthly basis, from cash flow generated by Seller, after deposits of amounts
into the Major Maintenance Reserve Account established pursuant to Seller's
financing documents, but prior to distributions to Seller or its members, any
applicable and unpaid Non-Dispatch Payment and a PRO RATA amount of the maximum
FCVR amount that Xxxxxxxx may earn prior to the next payment to the Lenders.
Amounts held in the Major Maintenance Reserve Account shall be used to pay, to
the extent owed, the FCVR and any Non-Dispatch Payments (provided that if there
shall be insufficient funds in the Major Maintenance Reserve Account to pay the
full-amount of any FCVR and any Non-Dispatch Payments then owed, Seller shall
not be relieved of its obligation to pay such FCVR or Non-Dispatch Payments).
Seller covenants that the foregoing provisions in its financing documents will
not be amended, modified, waived or terminated without the prior written consent
of Xxxxxxxx.
38
ARTICLE XI: DISPUTE RESOLUTION
SECTION 11.1 Third Party Engineer
(a) If Seller and Xxxxxxxx are in dispute with respect to any matter
addressed in Sections 2.2, 5.4, Article IX, Section 10.2 or 10.3 and Seller and
Xxxxxxxx do not resolve the dispute within seven (7) Days of Seller or Xxxxxxxx
notifying the other Party in writing of the existence of such dispute, a
committee consisting of two officers of Seller and two officers of Xxxxxxxx
shall meet and attempt in good faith to resolve such dispute. If such committee
does not resolve the dispute within seven (7) Days following their initial
meeting, then a single third party engineer (the "Third Party Engineer") shall
be designated to consider and decide the issues raised by such dispute unless
both Parties determine that further discussions by the committee are merited.
The selection of such Third Party Engineer shall be made from the list of
engineers set forth in Appendix 7 hereto (as supplemented or otherwise modified
from time to time pursuant to paragraphs (e) and (f) below). In selecting the
Third Party Engineer, each Party (starting with Seller for the first dispute and
alternating between Seller and Xxxxxxxx for each dispute thereafter) shall
alternate in deleting one name from the list of engineers until only one such
engineer shall remain, which remaining engineer shall be the Third Party
Engineer. The Third Party Engineer shall be designated from such list not later
than the third (3rd) Business Day following the expiration of the second seven
(7) Day period described above and such designation shall become effective on
the third (3rd) Business Day following such designation. Within ten (10)
Business Days of the effectiveness of the designation of a Third Party Engineer,
each of Seller and Xxxxxxxx shall submit to the Third Party Engineer a
confidential notice (a "Position Notice") setting forth in detail such Party's
position in respect of the issues in dispute. Such Position Notice shall include
supporting documentation, if appropriate.
(b) The Third Party Engineer shall complete all proceedings and issue
its decision with regard to the issues in dispute as promptly as reasonably
possible, but in any event within ten (10) Business Days of the date on which
both Position Notices are submitted unless the Third Party Engineer reasonably
determines that additional time is required in order to give adequate
consideration to the issues raised. In such case the Third Party Engineer shall
state in writing his reasons for believing that additional time is needed and
shall specify the additional period required, which period shall not exceed ten
(10) Days without Seller's and Xxxxxxxx' agreement.
(c) In resolving a dispute, the Third Party Engineer shall consider all
facts and circumstances it deems reasonable given the nature of the dispute.
(d) The Third Party Engineer shall choose either Seller's position or
Xxxxxxxx' position as set forth in their respective Position Notices. If the
Third Party Engineer determines that the position set forth in Seller's Position
Notice is correct, it shall so state and shall state the appropriate actions to
be taken by Xxxxxxxx. In such case, Xxxxxxxx shall promptly take such action. If
the Third Party Engineer determines that the position
39
set forth in Xxxxxxxx' Position Notice is correct, he shall so state and shall
state the appropriate actions to be taken by Seller. In such case, Seller shall
promptly take such actions. The decision of the Third Party Engineer shall be
final and non-appealable. The Seller and Xxxxxxxx shall each bear one-half of
all reasonable costs incurred by the Third Party Engineer in connection with a
dispute under this Section 11.1.
(e) The list of engineers referred to in paragraph (a) above shall
contain qualified engineers with experience in the design, operation and
maintenance of electric generating facilities. The initial such list shall be
proposed by Seller no later than sixty (60) Days after the Execution Date and
upon agreement of the Parties shall be incorporated into this Agreement as
Appendix 7. A Party may at any time remove a particular engineer from the list
by obtaining the other Party's reasonable consent to such removal. However,
neither Party may remove a name or names from the list if such removal would
leave the list without at least three (3) names after giving effect to any
concurrent addition of names pursuant to paragraph (f) below.
(f) During January of each year, each of Seller and Xxxxxxxx shall
review the current list of Third Party Engineers and give notice to the other of
any proposed additions to the list and any intended deletions. Intended
deletions shall automatically become effective thirty (30) Days after notice is
received by the other Party unless written objection is made by the other Party
within such thirty (30) Days and provided that such deletions do not leave the
list without at least three (3) names after giving effect to any concurrent
addition of names pursuant to this paragraph (f). Proposed additions to the list
shall automatically become effective thirty (30) Days after notice is received
by the other Party unless written objection is made by such other Party within
thirty (30) Days. By mutual agreement between Seller and Xxxxxxxx, a new name or
names may be added to the list of Third Party Engineers at any time.
SECTION 11.2 Designated Representatives
(a) Each of Seller and Xxxxxxxx shall designate in writing to the other
Party from time to time a representative who shall be authorized to resolve any
dispute relating to the subject matter of this Agreement not subject to the
provisions of Section 11.1 and, unless otherwise expressly provided herein, to
exercise the authority of such Party to make decisions by mutual agreement.
(b) The Parties agree (i) to attempt to resolve all disputes arising
hereunder promptly, equitably and in a good faith manner, and (ii) to provide
each other with reasonable access during normal business hours to any and all
non-privileged records, information and data pertaining to any such dispute.
(c) If any dispute is not resolved between the Parties pursuant to this
Section 11.2 within thirty (30) Days from the date on which a Party provided to
the other Party a written notice of such dispute, then such dispute shall be
settled exclusively and finally by arbitration in accordance with Section 11.3,
except for technical disputes, as described in Section 11.1 above, which shall
be resolved in accordance with that Section.
40
SECTION 11.3 Arbitration
(a) It is specifically understood and agreed that any dispute,
controversy or claim under this Agreement that cannot be resolved between the
Parties within the time period specified in Section 11.2(c), including any
matter relating to the interpretation of this Agreement but excluding any matter
to be submitted to the Third Party Engineer pursuant to Section 11.1, shall be
submitted to arbitration irrespective of the magnitude thereof, the amount in
dispute or whether such dispute would otherwise be considered justifiable or
ripe for resolution by any court or arbitral tribunal.
(b) Each arbitration between the Parties shall be finally settled in
Washington, D.C. conducted pursuant to the then applicable Commercial
Arbitration Rules of the American Arbitration Association.
(c) The arbitration shall be conducted before a tribunal composed of
three arbitrators. Each Party shall appoint an arbitrator, obtain its
appointee's acceptance of such appointment and deliver written notification of
such appointment and acceptance to the other Party within fifteen (15) Days
after the expiration of the thirty (30) Day period specified in Section 11.2(c).
The two Party-appointed arbitrators shall jointly appoint the third (who shall
be the chairperson), obtain the acceptance of such appointment and deliver
written notification of such appointment within fifteen (15) Days after their
appointment and acceptance. The arbitrators shall have the power and authority
to determine the arbitrability of any dispute arising under or relating to this
Agreement or the subject matter hereof.
(d) Any arbitration commenced hereunder shall be completed within
one-hundred twenty (120) Days of the appointment of the arbitral tribunal,
absent agreement of the Parties to an extension of such period. The Parties
shall be entitled to no discovery, provided, however, that the tribunal may
permit document discovery upon a showing of good cause. All direct testimony
shall be offered by way of affidavit. The Party submitting an affidavit shall
make the affiant available for cross-examination before the tribunal. The
Parties waive any claim to any damages in the nature of special, punitive,
exemplary, consequential or statutory damages in excess of compensatory damages,
and the tribunal is specifically divested of any power to award such damages.
All decisions of the tribunal shall be pursuant to a majority vote. Any interim
or final award shall be rendered by written decision. The judgment of the
tribunal shall be final and binding (i.e., not subject to appeal) on the
Parties. The Parties agree that a judgment upon any arbitration award may be
entered by any court having jurisdiction thereof.
(e) If a Party fails to appoint its arbitrator within a period of
fifteen (15) Days after receiving notice of the arbitration, or if the two
arbitrators appointed cannot agree upon the third arbitrator within a period of
fifteen (15) Days after appointment of the second arbitrator, then such
arbitrator shall be appointed by the American Arbitration Association.
41
(f) No arbitrator shall be a past or present employee or agent of; or
consultant or counsel to, either Party or any Affiliate of either Party, unless
such restriction is waived in writing by the other Party.
(g) Each Party shall pay the costs of its designated arbitrator (or the
arbitrator designated upon its failure to designate an arbitrator pursuant to
Section 11.3(f)) and one-half of the costs of the third arbitrator and
out-of-pocket third party costs and expenses of an arbitration under this
Section 11.3.
SECTION 11.4 Survival of Article
This Article XI shall survive the termination or expiration of this
Agreement.
ARTICLE XII: REPRESENTATIONS, WARRANTIES AND COVENANTS
SECTION 12.1 By Seller
Seller hereby represents, warrants and covenants as follows:
(a) Seller is a limited liability company duly organized and validly
existing under the laws of the State of Delaware.
(b) Seller has all requisite power and authority to carry on the
business to be conducted by it under this Agreement and to enter into and
perform its obligations under this Agreement.
(c) The execution and delivery of this Agreement and the performance of
Seller's obligations hereunder have been duly authorized by all necessary action
on the part of Seller and do not and will not conflict with or result in a
breach of Seller's certificate of formation or limited liability company
agreement or any indenture, mortgage, other agreement or instrument or any
statute or rule, regulation, order, judgment or decree of any judicial or
administrative body to which Seller is a party or by which Seller or any of its
properties is bound or subject.
(d) This Agreement is the valid and binding obligation of Seller,
enforceable with its terms, except as such enforceability may be limited by
applicable bankruptcy, insolvency or similar laws from time to time in effect
that affect creditors' rights generally or by general principles of equity.
(e) Seller is in compliance with the material provisions of all laws
which are applicable to it or its operations, non-compliance with which could
reasonably be expected to have a material adverse effect on the ability of
Seller to perform its obligations under this Agreement including, without
limitation, Environmental Laws.
(f) Other than those identified in Paragraph (g) below, there are no
enforcement, clean-up, removal, mitigation or other governmental or regulatory
actions,
42
claims or proceedings, including but not limited to any proceedings
relating to damage, contribution, cost recovery, compensation, Loss or injury,
pending or to Seller's knowledge threatened, under any Environmental Law
affecting the Facility or the Site, which would reasonably be expected to have a
material adverse effect on the ability of Seller to perform its obligations
under this Agreement.
(g) Seller has identified soil contamination at the Site which is
currently being addressed in accordance with the New Jersey Department of
Environmental Protection requirements. The aforementioned soil contamination is
not reasonably expected to have a material adverse effect on the ability of
Seller to perform its obligations under this Agreement.
SECTION 12.2 By Xxxxxxxx
Xxxxxxxx hereby represents, warrants and covenants as follows:
(a) Xxxxxxxx is a corporation duly organized and validly existing under
the laws of the State of Delaware.
(b) Xxxxxxxx has all requisite power and authority to carry on the
business to be conducted by it under this Agreement and to enter into and
perform its obligations under this Agreement.
(c) The execution and delivery of this Agreement and the performance of
Xxxxxxxx' obligations hereunder have been duly authorized by all necessary
action on the part of Xxxxxxxx and do not and will not conflict with or result
in a breach of Xxxxxxxx' charter documents or by-laws or any indenture,
mortgage, other agreement or instrument of any statute or rule, regulation,
order, judgment or decree of any judicial or administrative body to which
Xxxxxxxx is a party or by which Xxxxxxxx or any of its Affiliates is bound or
subject.
(d) This Agreement is the valid and binding obligation of Xxxxxxxx,
enforceable with its terms except as such enforceability may be limited by
applicable bankruptcy, insolvency or similar laws from time to time in effect
that affect creditors' rights generally or by general principles of equity.
(e) Xxxxxxxx is in compliance with the material provisions of all laws
which are applicable to it or its operations, non-compliance with which could
reasonably be expected to have a material adverse effect on the ability of
Xxxxxxxx to perform its obligations under this Agreement including, without
limitation, Environmental Laws.
43
ARTICLE XIII: LIABILITY, DEDICATION
SECTION 13.1 Third Parties
Nothing in this Agreement shall be construed to create any duty,
standard of care or liability to any Person not a Party to this Agreement.
SECTION 13.2 Limitation of Liability
Notwithstanding anything contained in this Agreement, except with
respect to indemnified third party claims, in respect of which this Section 13.2
shall not apply, neither Party shall be liable to the other Party, its
Affiliates, directors, officers, partners, agents, employees, successors or
assigns, for claims for incidental, special, punitive, indirect or consequential
damages of any nature arising out of; connected with or resulting from
performance or nonperformance of this Agreement, including, without limitation,
claims in the nature of lost revenues, income or profits (other than payments
specifically provided for and properly due under this Agreement) or Losses,
damages or liabilities under any financing, lending or construction contracts,
agreements or arrangements to which Seller may be party irrespective of whether
such claims are based upon warranty, negligence, strict liability, contract,
operation of law or otherwise. The provisions of this Section 13.2 shall survive
the termination or expiration of this Agreement.
SECTION 13.3 No Dedication to the Public
No undertaking by either Party under any provision of this Agreement
shall constitute the dedication of that Party's electrical reserves, system,
equipment, or facilities, or any portion thereof; to the other Party or to the
public.
ARTICLE XIV: INDEMNITY
SECTION 14.1 Indemnity
Subject to the provisions of Section 14.3, each Party shall indemnify,
hold harmless and defend the other Party, its Affiliates, directors, officers,
partners, agents and employees from and against any and all Loss, liability,
damage, cost or expense, including damage and liability for bodily injury to or
death of third Persons or damage to property of third Persons (collectively,
"Loss"), to the extent arising out of; in connection with or resulting from the
indemnifying Party's breach of any of the representations or warranties made in,
or the indemnifying Party's failure to perform any of its obligations under,
this Agreement, or the indemnifying Party's design, installation, construction,
ownership, operation, repair, relocation, replacement, removal or maintenance
of; or the failure of; any of such Party's equipment and/or facilities,
including, but not limited to, the Interconnection Facilities, the Facility,
Natural Gas Interconnection Facilities and
44
Protective Gas Apparatus and any Natural Gas facilities, and/or any
appurtenances thereto, and any electric transmission facilities used in
connection with this Agreement; provided, however, that neither Party shall have
any indemnification obligations hereunder in respect of any Loss to the extent
caused by such other Party's gross negligence, bad faith or willful misconduct.
Each Party hereto shall furnish the other Party with written notification after
such Party becomes aware of any event or circumstances, or the threat thereof;
(but in no event later than ten (10) Days prior to the time any response is
required by law) which might give rise to such indemnification. At the
indemnified Party's request, the indemnifying Party shall defend any suit
asserting a claim covered by this indemnity and shall pay any and all costs and
expenses (including reasonable attorney's fees and expenses) that may be
incurred, including any and all costs and expenses which may be incurred by the
indemnified Party, in enforcing this indemnity. The indemnified Party may, at
its own expense, retain separate counsel and participate in the defense of any
such suit or action.
SECTION 14.2 Environmental Indemnity
(a) Subject to the terms and provisions of this indemnity and the
provisions of Sections 14.1, Seller shall protect, defend, indemnify and save
harmless Xxxxxxxx, its officers, directors, shareholders, agents, employees,
successors, assigns and attorneys (collectively, the "Indemnified Parties")
from, against and in respect of, any and all Losses, costs, damages,
liabilities, obligations, claims, causes of action, fines, penalties or expenses
(including reasonable attorney's fees, expenses and litigation costs and sums
paid in settlements of claims and any such fees and expenses incurred in
enforcing this indemnity or collecting any sums due hereunder) and reasonable
expenses for accounting, consulting, engineering, investigation, cleanup,
response, removal and/or disposal and other remedial costs, directly or
indirectly imposed upon, incurred by or asserted against any Indemnified Party
arising out of or in connection with any claim or claims by any other party or
parties (including, without limitation, a governmental authority), arising out
of or in connection with (i) the use, generation, refining, manufacture,
transportation, transfer, production, processing, storage, handling, or
treatment of any Hazardous Materials, on, under or from the Facility; (ii) a
release, or threatened release of any Hazardous Materials on, under or from the
Facility (other than such a release resulting from an action of Xxxxxxxx, its
contractors or its Transporters) (iii) the cleanup, removal and/or disposal of
any Hazardous Materials (other than Hazardous Materials released by Xxxxxxxx,
its contractors or its Transporters) on, under or from the Facility required by
any Environmental Law or any governmental authority; (iv) any personal exposure
or injury (including wrongful death) or property damage (real or personal)
arising out of or related to such Hazardous Materials, including any damage
arising out of any cleanup required by the governmental authorities or
Environmental Laws; (v) any lawsuit brought or threatened, settlement reached,
or government order relating to such Hazardous Materials; or (vi) any violation
of laws, orders, rules, regulations, requirements, guidelines, or demands of
governmental authorities, including permits and licenses under Environmental
Laws, which are based upon or in any way related to such Hazardous Materials
including, without limitation, the costs and expenses of any remedial action,
45
reasonable attorney and consultant fees, investigation and laboratory fees,
court costs and litigation expenses; or (vii) a misrepresentation or inaccuracy
in any representation or warranty made by Seller in Section 12.1 of this
Agreement.
(b) Subject to the terms and provisions of this indemnity and the
provisions of Sections 14.1, Xxxxxxxx shall protect, defend, indemnify and save
harmless Seller, its officers, directors, shareholders, agents, employees,
successors, assigns and attorneys (collectively, the "Indemnified Parties")
from, against and in respect of, any and all Losses, costs, damages,
liabilities, obligations, claims, causes of action, fines, penalties or expenses
(including reasonable attorney's fees, expenses and litigation costs and sums
paid in settlements of claims and any such fees and expenses incurred in
enforcing this indemnity or collecting any sums due hereunder) and reasonable
expenses for accounting, consulting, engineering, investigation, cleanup,
response, removal and/or disposal and other remedial costs, directly or
indirectly imposed upon, incurred by or asserted against any Indemnified Party
arising out of or in connection with any claim or claims by any other party or
parties (including, without limitation, a governmental authority), arising out
of or in connection with (i) the use, generation, refining, manufacture,
transportation, transfer, production, processing, storage, handling, treatment
or release or threatened release of any Hazardous Materials resulting from the
actions of Xxxxxxxx, its contractors or its Transporters related to this
Agreement or otherwise, on, under or from the Facility; (ii) the cleanup,
removal and/or disposal of any Hazardous Materials released by Xxxxxxxx, its
contractors or its Transporters on, under or from the Facility required by any
Environmental Law or any governmental authority; (iii) any personal exposure or
injury (including wrongful death) or property damage (real or personal) arising
out of or related to such Hazardous Materials, including any damage arising out
of any cleanup required by the governmental authorities or Environmental Laws;
(iv) any lawsuit brought or threatened, settlement reached, or government order
relating to such Hazardous Materials; or (v) any violation of laws, orders,
rules, regulations, requirements, guidelines, or demands of governmental
authorities, including permits and licenses under Environmental Laws, which are
based upon or in any way related to such Hazardous Materials including, without
limitation, the costs and expenses of any remedial action, reasonable attorney
and consultant fees, investigation and laboratory fees, court costs and
litigation expenses.
SECTION 14.3 Claims by Employees
The indemnity in Section 14.1 shall apply to all claims against each
Party including, but not limited to, all claims made or threatened by, or in the
name of or on behalf of each Party's employees for personal injuries (including
death) which arise in the course of their employment. Seller hereby waives any
defense it may otherwise have under applicable workers' compensation laws.
46
SECTION 14.4 Risk of Loss
As between the Parties, Xxxxxxxx shall be deemed to be in exclusive
possession and control (and responsible for any damages or injury resulting
therefrom or caused thereby) of Natural Gas prior to the Natural Gas Delivery
Point and Net Electric Energy and Ancillary Services at and from the Primary
Delivery Point, and Seller shall be deemed to be in exclusive possession and
control (and responsible for any damages or injury resulting therefrom or caused
thereby) of Natural Gas at and from the Natural Gas Delivery Point and Net
Electric Energy and Ancillary Services prior to the Primary Delivery Point. Risk
of Loss related to Natural Gas shall transfer from Xxxxxxxx to Seller at the
Natural Gas Delivery Point and Risk of Loss related to the Net Electric Energy
and Ancillary Services shall transfer from Seller to Xxxxxxxx at the Primary
Delivery Point. Xxxxxxxx shall indemnify, defend and hold harmless Seller from
and against any Loss arising out of or in any way relating to Xxxxxxxx'
possession or control of Natural Gas prior to the Natural Gas Delivery Point or
its possession and control of the Net Electric Energy and Ancillary Services at
and after the Primary Delivery Point, and Seller shall indemnify, defend and
hold harmless Xxxxxxxx from and against any Loss arising out of or in any way
relating to Seller's possession or control of Natural Gas at and after the
Natural Gas Delivery Point or the Net Electric Energy and Ancillary Services
prior to the Primary Delivery Point.
SECTION 14.5 Survival of Article
The Parties expressly acknowledge and agree that this Article XIV shall
survive the termination or expiration of this Agreement.
ARTICLE XV: INSURANCE
SECTION 15.1 Insurance Generally
Seller and the operator of the Facility (including their respective
successors and assigns) shall each procure and shall maintain the following
insurance coverage for the Facility so long as such insurance is available on
commercially reasonable terms. The limits set forth below are minimum limits and
will not be construed to limit Seller's or operator's liability:
(a) Workers' Compensation insurance complying with the laws of the
state or states having jurisdiction over each employee, and Employer's Liability
with limits of $1,000,000 each accident, $1,000,000 disease each employee, and
$1,000,000 disease policy limit.
(b) Commercial or Comprehensive General Liability insurance on an
occurrence form with a combined single limit of $1,000,000 each occurrence, and
annual aggregates of $1,000,000, for bodily injury and property damage,
including coverage for blanket contractual liability, broad form property
damage, personal injury liability,
47
independent contractors, products/completed operations, sudden and accidental
pollution liability and the explosion, collapse and underground exclusion will
be deleted.
(c) Automobile Liability insurance with a combined single limit of
$1,000,000 each occurrence for bodily injury and property damage to include
coverage for all owned, non-owned, and hired vehicles.
(d) Excess or Umbrella Liability insurance with a combined single limit
of $10,000,000 each occurrence, and annual aggregates of $10,000,000 for bodily
injury and property damage covering excess of Employers Liability and the
insurance described in (b) and (c) above.
SECTION 15.2 Risk Insurance
Seller shall purchase and maintain all risk property insurance,
including the perils of flood and earthquake covering all property, material and
equipment comprising the facility, during construction, while in transit, during
loading and unloading, while in storage, while at another location for repair
and during installation in an amount not less than the total cost to replace the
Facility with like kind and quality on a new or old basis per occurrence for
property damage. This insurance shall include boiler and machinery insurance and
coverage for delayed startup of business, business interruption and expediting
expense. This insurance shall include the interests of the Seller's
Subsidiaries, operator and Xxxxxxxx.
SECTION 15.3 Copies
(a) Not less than ten (10) Days prior to the commencement of
construction of the Facility, Seller shall provide and shall continue to provide
to Xxxxxxxx annually during the Term of this Agreement certificates of insurance
evidencing coverage required by this Article 15 on a form satisfactory to
Xxxxxxxx with insurance companies rated A IX or better by A.M. Best.
Certificates shall provide at minimum the following information:
(i) Name of insurance company, policy number and expiration
date;
(ii) The coverage required and the limits on each, including
the amount of deductibles or self insured retentions;
(iii) Thirty (30) Days prior written notice of cancellation
with respect to all insurance policies required hereunder, except in
respect of cancellation for non payment of premiums for which such
prior written notice shall be ten (10) days;
(iv) For all insurance policies except Workers' Compensation
insurance, endorsements indicating that Xxxxxxxx has been named as an
additional insured;
48
(v) All policies shall include a waiver of rights or
subrogation clause in favor of Xxxxxxxx.
(b) Irrespective of the insurance requirements above, the insolvency,
bankruptcy, or failure of any such insurance company providing insurance for
Seller's Subsidiaries, or the failure of any such insurance company to pay
claims that occur will not be held to waive any of the provisions hereof.
(c) In the event any Lender requires higher limits, broader coverage or
lower retentions Xxxxxxxx will also receive the benefit of such insurance
coverages.
ARTICLE XVI: FORCE MAJUERE
SECTION 16.1 Excused Performance
(a) A Party shall be excused from performing its obligations under this
Agreement and shall not be liable in damages or otherwise to the other Party if
and to the extent such Party declares that it is unable to perform or is
prevented from performing an obligation under this Agreement by a Force Majeure
condition, except for any obligations and/or liabilities under this Agreement to
pay money, which shall not be excused, and except to the extent an obligation
accrues prior to the occurrence or existence of a Force Majeure condition,
provided that:
(i) the Party declaring its inability to perform by virtue of
Force Majeure, as promptly as practicable after the occurrence of the
Force Majeure condition, but in no event later than five (5) Days
thereafter, gives the other Party written notice describing, in detail,
the nature, extent and expected duration of the Force Majeure
condition;
(ii) the suspension of performance is of no greater scope and
of no longer duration than is reasonably required by the Force Majeure
condition;
(iii) the Party declaring Force Majeure uses all commercially
reasonable efforts to remedy its inability to perform; and
(iv) as soon as the Party declaring Force Majeure is able to
resume performance of its obligations excused as a result of the Force
Majeure condition, it shall give prompt written notification thereof to
the other Party.
(b) Irrespective of whether the Force Majeure condition is declared by
Xxxxxxxx or Seller, the time period of a Force Majeure that prevents Seller from
delivering or providing Net Electric Energy, Unforced Capacity or Ancillary
Services hereunder shall be excluded from the calculation of all payments under
Appendix 1 and Xxxxxxxx shall be under no obligation to pay Seller any of the
payments described in Appendix 1 for such time period except that, if Xxxxxxxx
declares a Force Majeure, it
49
shall, subject to Section 16.4 and subject to the limitation in Section 8.3(a)
continue to pay Seller only the applicable monthly Total Fixed Payment as
described in Section II.A.2 of Appendix 1, until the earlier of (i) the
termination of the Force Majeure condition or (ii) the termination of this
Agreement, and provided further that in the event of a Force Majeure declared by
Seller due to an action or inaction of the Host Utility that prevents Seller
from delivering Net Electric Energy to the Primary Delivery Point, [*].
SECTION 16.2 Exclusions from Force Majeure
Notwithstanding anything to the contrary contained in this Agreement,
except as may expressly be provided herein, the term Force Majeure shall not
include or excuse a Party's performance in the following circumstances:
(a) Except as otherwise set forth in Section 2.1, the failure to
complete the Facility by or to achieve the Commercial Operation Date as extended
pursuant to Section 2.1 and Section 18.4, which failure is caused by, arises out
of or results from the acts or omissions of Seller, and/or from the acts or
omissions of any third party, unless, and then only to the extent that, any such
acts or omissions of such third party (i) would itself be excused hereunder by
virtue of a Force Majeure condition, or (ii) is the result of Xxxxxxxx' failure
to provide Natural Gas to the Facility;
(b) Any reduction, curtailment or interruption of generation or
operation of the Facility, or of the ability of Xxxxxxxx to accept or transmit
Net Electric Energy, whether in whole or in part, which reduction, curtailment
or interruption is caused by or arises from the acts or omissions of any third
party providing services or supplies to the Party claiming Force Majeure,
including any vendor or supplier to either Party of materials, equipment,
supplies or services, or any inability of the Host Utility to deliver Net
Electric Energy to Xxxxxxxx, unless, and then only to the extent that, any such
acts or omissions would itself be excused hereunder as a Force Majeure;
(c) Any outage, whether or not due to the fault or negligence of
Seller, of the Facility attributable to a defect or inadequacy in the
manufacture, design or installation of the Facility that prevents, curtails,
interrupts or reduces the ability of the Facility to generate Net Electric
Energy or the ability of Seller to perform its obligations hereunder;
(d) To the extent that the Party claiming Force Majeure failed to
prevent or remedy the Force Majeure condition by taking all commercially
reasonable acts (short of litigation, if such remedy requires litigation) and,
except as otherwise provided in Section 16.3 below, failed to resume performance
hereunder with reasonable dispatch after the termination of the Force Majeure
condition;
(e) To the extent that the claiming Party's failure to perform was
caused by lack of funds;
50
(f) Any inability of a Party to perform its obligations hereunder
because of an increase or decrease in the market price of Energy/capacity,
Natural Gas, or because it is uneconomic for such Party to perform such
obligations; and
(g) To the extent Xxxxxxxx is unable to perform due to a shortage of
Natural Gas not caused by an event of Force Majeure.
SECTION 16.3 Labor Disputes
Notwithstanding anything contained in this Article XVI to the contrary,
neither Party shall be required to settle any strike, walkout, lockout or other
labor dispute on terms which, in the sole judgment of the Party involved in the
dispute, are contrary to its interest, it being understood and agreed that the
settlement of strikes, walkouts, lockouts or other labor disputes shall be
entirely within the discretion of the Party having such dispute.
SECTION 16.4 Termination from Force Majeure
Notwithstanding anything contained in this Article XVI to the
contrary, Xxxxxxxx shall have the right to terminate this Agreement, without
any liability or responsibility whatsoever, except to the extent accruing
(and not excused) prior to such termination, in the event Force Majeure has
been declared by Seller and the effect of said Force Majeure has not been
fully corrected or alleviated within [*] months after the date said Force
Majeure was declared; provided, however, that Xxxxxxxx shall not have the
right to terminate this Agreement in the event that the Force Majeure event
was caused by Xxxxxxxx, or if the Force Majeure event does not prevent or
materially limit Xxxxxxxx' ability to sell Unforced Capacity from the
Facility into or through the PJM market or to a third party.
SECTION 16.5 Extension from Force Majeure
Upon notice from Xxxxxxxx to Seller no later than ninety (90) days
prior to the end of the initial Term, the Term shall be extended for a period
of up to a total of [*] for each hour of such initial Term during which
Seller is unable to deliver Energy and/or Ancillary Services because of an
event of Force Majeure (other than an inability of Seller to obtain Natural
Gas to operate the Facility) that occurs after the Commercial Operation Date.
ARTICLE XVII: EVENTS OF DEFAULT; TERMINATION, REMEDIES
SECTION 17.1 Events of Default
The following shall constitute events of default under this Agreement:
51
(a) A breach of any term or condition of this Agreement, including, but
not limited to, (i) any failure to maintain or to renew any security as required
by Article 18 of this Agreement, (ii) any breach of a representation, warranty
or covenant made in this Agreement including the Appendices hereto, or (iii)
failure of either Party to make a required payment to the other Party of amounts
due hereunder.
(b) The Facility is not available to provide the Fuel Conversion
Services or Ancillary Services to Xxxxxxxx during any period of [*]
consecutive Days after the occurrence of the Commercial Operation Date for
any reason, except as may be excused by Force Majeure, the absence of
available Natural Gas, or such non-availability is caused by an act or
failure to act by Xxxxxxxx where such action is required by this Agreement.
(c) Seller sells or supplies Net Electric Energy, Ancillary Services or
Unforced Capacity from the Facility, or agrees to do the same, to any Person or
entity other than Xxxxxxxx, without the prior approval of Xxxxxxxx.
(d) Without duplication of the [*] Day period in Section 17.2,
Seller fails for [*] consecutive Days, after notification from Xxxxxxxx
providing a reasonable opportunity to cure, to perform regular and required
maintenance, testing or inspection of the Interconnection Facilities, the
Facility and/or other electric equipment and facilities as required by this
Agreement where such failure is material.
(e) Without duplication of the [*] Day period in Section 17.2,
Seller fails for [*] consecutive Days, after notification from Xxxxxxxx
providing a reasonable opportunity to cure, to correct or resolve a material
violation of any code, regulation and/or statute applicable to the
construction, installation, operation or maintenance of the Facility, the
Interconnection Facilities, Protective Gas Apparatus or any other electric
equipment and facilities required to be constructed and operated under this
Agreement when such violation impairs the continued ability of Seller to
perform its obligations under this Agreement.
(f) A receiver or liquidator or trustee of either Party or of any of
its property shall be appointed by a court of competent jurisdiction, and such
receiver, liquidator or trustee shall not have been discharged within [*]
Days or by decree of such a court a Party shall be adjudicated bankrupt or
insolvent or any substantial part of its property shall have been sequestered,
and such decree shall have continued undischarged and unstayed for a period of
[*] Days after the entry thereof or a petition to declare bankruptcy or
to reorganize a Party pursuant to any of the provisions of the Federal
Bankruptcy Code, as now in effect or as it may hereafter be amended, or pursuant
to any other similar state statute as now or hereafter in effect, shall be filed
against a Party and shall not be dismissed within [*] Days after such
filing.
(g) A Party shall file a voluntary petition in bankruptcy under any
provision of any federal or state bankruptcy law or shall consent to the filing
of any bankruptcy or reorganization petition against it under any similar law;
or, without limiting the generality
52
of the foregoing, a Party shall file a petition or answer or consent seeking
relief or assisting in seeking relief in a bankruptcy under any provision of any
federal or state bankruptcy law or shall consent to the filing of any bankruptcy
or reorganization petition against it under any similar law; or, without
limiting the generality of the foregoing, a Party shall file a petition or
answer or consent seeking relief or assisting in seeking relief in a proceeding
under any of the provisions of the Federal Bankruptcy Code, as now in effect or
as it may hereafter be amended, or pursuant to any other similar state statute
as now or hereafter in effect, or an answer admitting the material allegations
of a petition filed against if in such a proceeding; or a Party shall make an
assignment for the benefit of its creditors; or a Party shall submit in writing
its inability to pay its debts generally as they become due; or a Party shall
consent to the appointment of a receiver, trustee, or liquidator of it or of all
or any part of its property.
(h) Any modifications, alterations or other changes to the Facility by
or on behalf of Seller which prevent Seller from fulfilling, or materially
diminish Seller's ability to fulfill, its obligations, duties, rights and
responsibilities hereunder and which, after reasonable notice and opportunity to
cure, are not corrected.
(i) The AES Corporation shall cease to own, directly or indirectly,
beneficially and of record, at least fifty (50) percent of the equity interests
in Seller, or shall cease to possess the power to direct or cause the direction
of the management or policies of Seller, or any Person (other than The AES
Corporation or an Affiliate) authorized to act as a power marketer by FERC or
any Affiliate of such a Person shall own, directly or indirectly, beneficially
or of record, any of the equity interests in Seller.
(j) There shall be outstanding for more than [*] Days any
unsatisfied final, non-appealable judgment against Seller in an amount
exceeding [*], unless the existence of such unsatisfied judgment shall not
materially affect Seller's ability to perform its obligations under this
Agreement.
SECTION 17.2 Cure and Termination
(a) Upon the occurrence of any event of default described in Section
17.1 (other than an event of default under Section 17.1(f) or (g) hereof for
which no notice shall be required or opportunity to cure permitted), the Party
not in default, to the extent such Party has actual knowledge of the occurrence
of such event of default, shall give prompt written notice of the default to the
defaulting Party. Such notice shall set forth, in reasonable detail, the nature
of the default and, where known and applicable, the steps necessary to cure such
default. The defaulting Party shall have [*] Days ([*] Business Days
in the case of a default under Section 17.1 (a)(iii)) following receipt of such
notice either to (i) cure such default or (ii) commence in good faith all such
steps as are necessary and appropriate to cure such default in the event such
default cannot be completely cured within such [*] Day period.
(b) If the defaulting Party fails to cure such default or take such
steps as provided under subparagraph (a) above, and immediately upon the
occurrence of any
53
event of default described in Section 17.1(g) hereof, this Agreement may be
terminated by the non-defaulting Party, without any liability or responsibility
whatsoever, by written notice to the Party in default hereof. This Agreement
shall thereupon terminate and the non-defaulting Party may exercise all such
rights and remedies as may be available to it to recover damages caused by such
default.
(c) Notwithstanding the foregoing, upon the occurrence of any such
event of default, the non-defaulting Party shall be entitled to (i) commence an
action to require the defaulting Party to remedy such default and specifically
perform its duties and obligations hereunder in accordance with the terms and
conditions hereof and (ii) exercise such other rights and remedies as it may
have in equity or at law subject, however, to the limitation of liability
provided in Article 13.2 hereof.
ARTICLE XVIII: SECURITY
SECTION 18.1 Indemnity for Delay
Without limiting the general applicability of the provisions of Article
II, or this Article, if the Commercial Operation Date does not occur by the
Final CO Date, as such date may be extended pursuant to the provisions of
Section 2.1 and Section 18.4, Seller agrees to compensate Xxxxxxxx for any
actual damages it suffers or incurs as the result of Xxxxxxxx' reliance upon the
delivery of Facility Capacity, Ancillary Services and Fuel Conversion Services
hereunder, to the extent said damages cannot be mitigated fully. Seller further
agrees that the damages Xxxxxxxx may suffer under these circumstances will be
any and all reasonable costs incurred by Xxxxxxxx in excess of costs that would
have been incurred had the Commercial Operation Date occurred on or before
December 31, 2001, as such date may be extended pursuant to Section 2.1 and
Section 18.4.
SECTION 18.2 Seller's Guaranty
(a) In order to provide reasonable assurances to Xxxxxxxx that a Person
or entity on behalf of Seller shall fulfill Seller's potential liability under
this Article and otherwise under this Agreement, Seller shall provide to
Xxxxxxxx on the same day the Seller provides a Notice to Bind, (i) a guaranty of
Seller's performance and payment obligations under this Agreement from The AES
Corporation ("AES"), in the form attached hereto as Appendix 5 and made a part
hereof, in the amount of $[*] ("Guaranty Amount"), which Guaranty Amount
shall reduce to $[*] on the Commercial Operation Date and shall remain in
effect during the Term, or (ii) at any time at Seller's option, such financial
security for the Guaranty Amount as specified in Section 18.2(b) hereof.
(b) If Seller secures payment of the Guaranty Amount through financial
security other than the guaranty of AES, Seller shall provide to Xxxxxxxx
security in the form of a single letter of credit, satisfactory to Xxxxxxxx in
form and substance, upon which Xxxxxxxx
54
may draw if the Facility does not achieve the Commercial Operation Date by the
date specified in Section 2.2, as such date may be extended pursuant to such
Section and as such date may be extended by Section 18.4. In the event said
security contains an expiration date, either express or implied, Seller shall
renew said security not later than [*] Days prior to said expiration date
and shall contemporaneously therewith provide written notice of said renewal to
Xxxxxxxx. In the event Seller fails to renew said security as set forth above,
Xxxxxxxx shall be entitled to demand and receive payment thereunder on or after
[*] Days after written notice of such failure is provided to Seller and in
such event the amount so drawn shall be deposited in an interest bearing escrow
account and shall be returned to Seller at the Commercial Operation Date unless
otherwise drawn on by Xxxxxxxx in satisfaction of Seller's obligations under
Section 18.1 of this Agreement.
(c) The letter of credit referred to in paragraph (b) above shall be
issued by a financial institution that meets and at all times during the term of
such letter of credit maintains the following criteria:
(i) A U.S. or foreign bank rated "C" or better by Xxxxxxxx
Bankwatch; or
(ii) A U.S. or foreign bank, surety company or financial
institution whose senior debt has the rating listed below by two (2) of
the three (3) rating agencies:
Standard & Poor's: "A-" or better
Xxxxx'x: "A3" or better
Duff & Xxxxxx: "A-" or better
If such bank, surety company or financial institution fails to maintain
such criteria, then upon thirty (30) Days written notice from Xxxxxxxx,
Seller shall obtain equivalent security from another bank, surety
company or financial institution meeting the above stated criteria. The
form and substance of any such letter of credit shall be reasonably
satisfactory to Xxxxxxxx.
(d) Seller shall execute any and all documents reasonably necessary to
assure that Xxxxxxxx' claim to and interest in said security is perfected.
SECTION 18.3 Xxxxxxxx Guaranty
(a) If Xxxxxxxx provides a Notice to Proceed pursuant to Section
18.4, Xxxxxxxx shall provide [*], no later than [*] prior to the anticipated
financial closing, such date to be provided by Seller, a guaranty of
Xxxxxxxx' performance and payment obligations under this Agreement in the
form attached hereto as Appendix 6 and made a part hereof and issued by The
Xxxxxxxx Companies, Inc. ("TWC"), provided that the long term senior
unsecured debt of TWC is at such time rated Investment Grade or if the long
term senior unsecured debt of TWC is at such time not rated Investment Grade,
issued by an Affiliate of Xxxxxxxx whose long term senior
55
unsecured debt at such time is rated Investment Grade (TWC and any such other
guarantor hereinafter referred to as "Guarantor").
(b) [*]
56
[*]
ARTICLE XIX: SEVERAL OBLIGATIONS
SECTION 19.1 Several Obligations
Except where otherwise specifically stated in this Agreement, the
duties, obligations and liabilities of the Parties are intended to be several,
not joint or collective. Nothing contained in this Agreement shall ever be
construed to create an association, trust, partnership or joint venture or
impose a trust or partnership duty, obligation or liability on or with regard to
either Party. Each Party shall be individually and severally liable for its own
obligations under this Agreement.
ARTICLE XX: WAIVER
SECTION 20.1 No Continuing Waiver
Any waiver at any time by either Party of its rights, duties, and/or
obligations with respect to any default under this Agreement, or with respect to
any other matter arising out of or in connection with this Agreement, shall not
be deemed a continuing waiver nor a waiver with respect to any subsequent
default or other matter.
ARTICLE XXI: ASSIGNMENT
SECTION 21.1 Assignment
(a) Neither this Agreement nor any rights, duties, interests or
obligations hereunder may be assigned, transferred, pledged or otherwise
encumbered or disposed of by operation of law or otherwise without the prior
written consent of the other Party; except that (i) Xxxxxxxx, at any time after
reasonable advance notice to Seller and without the consent of Seller, may
assign this Agreement and any of its rights, interests, duties or obligations
hereunder to any Affiliate of Xxxxxxxx or any other entity, provided that such
Affiliate of Xxxxxxxx or such other entity's long term unsecured debt at such
time is rated Investment Grade by Standard & Poor's and Xxxxx'x or that such
Affiliate of Xxxxxxxx or
57
such other entity's obligations under this Agreement are guaranteed by an
Affiliate whose long term unsecured debt at such time is rated Investment Grade
by Standard & Poor's and Xxxxx'x and so long as any assignee shall agree to be
bound by all of the terms and conditions hereof to the same extent as Xxxxxxxx;
(ii) Seller, at any time, and from time to time, after reasonable advance notice
to Xxxxxxxx and without the consent of Xxxxxxxx, may assign this Agreement and
any of its rights, interests, duties or obligations hereunder as collateral
security to any Lender so long as the assignee shall agree to be bound by all of
the terms and conditions hereof to the same extent as Seller in the event the
Lender exercises its rights under such assignment; and (iii) Seller shall have
the right at any time without the consent of Xxxxxxxx to assign this Agreement
and its rights, interests, duties and obligations hereunder to any Affiliate,
provided that such Affiliate assumes in writing all of the obligations and
duties of Seller hereunder and the guaranty/security required pursuant to
Section 18.2 remains in effect. This Agreement shall inure to the benefit of and
bind the parties hereto, including any permitted assignee or successor.
(b) Except as otherwise specified in this Article XXI, no assignment or
disposition of rights hereunder shall (i) relieve or in any way discharge Seller
or Xxxxxxxx from the performance of their respective obligations and liabilities
under this Agreement or (ii) alter, amend, diminish or otherwise impair
Xxxxxxxx' or Seller's rights under this Agreement.
SECTION 21.2 Transfer of Facility
Seller hereby agrees that it shall not sell, transfer, assign, lease or
otherwise dispose of the Facility or any substantial portion thereof or interest
therein necessary to perform Seller's obligations hereunder to any Person that
is a FERC authorized power marketer or an Affiliate of such an entity without
the prior written consent of Xxxxxxxx, which consent shall not be unreasonably
withheld.
SECTION 21.3 Void Assignments or Transfers
Except as specifically provided for in this Article XXI, any assignment
or transfer of this Agreement or any rights, duties or interests hereunder or
any disposition of the Facility or any portion thereof or interest therein by
any Party without the written consent of the other Party as provided herein
shall be void and of no force or effect.
SECTION 21.4 Cost Reimbursement
Each Party shall reimburse the other for the reasonable costs and
expenses (including reasonable legal fees and expenses) incurred in connection
with a Party's agreement to review, execute and deliver any instruments,
agreements or documents that may be used in connection with any assignment
requested by a Party or otherwise permitted hereunder.
58
ARTICLE XXII: NOTICES
SECTION 22.1 Notice Requirements
All notices, demands, requests or other correspondence required or
permitted under this Agreement shall be in writing and shall be personally
delivered or sent by certified United States mail (postage prepaid, return
receipt requested), overnight express mail, courier service or facsimile
transmission (with the original transmitted by any of the other aforementioned
delivery methods) addressed as follows:
If to Seller to: AES Red Oak, L.L.C.
0000 X. 00xx Xxxxxx
Xxxxxxxxx, XX 00000
Attention: Project Manager
(Facsimile): 000-000-0000
If to Xxxxxxxx to: Xxxxxxxx Energy Marketing & Trading Company
Xxx Xxxxxxxx Xxxxxx
Xxxxx, XX 00000
Attention: Contract Management
(Facsimile): 000-000-0000
Attention: Dispatch and Technical Services
(Facsimile): 000-000-0000
or to such other Person at such other address as a Party shall designate by like
notice to the other Party.
SECTION 22.2 Timing
Unless otherwise provided herein, all notices hereunder shall be deemed
to be given when received or personally delivered.
ARTICLE XXIII: GRATUITIES
SECTION 23.1 No Gratuities
Each Party shall prohibit their employees from using their official
position for personal financial gain or from accepting any personal advantage
from anyone under circumstances which might reasonably be interpreted as an
attempt to influence the recipients in the conduct of their official duties.
Neither Party, nor their employees or representatives shall, under circumstances
which might reasonably be interpreted as an attempt to influence the recipients
in the conduct of their duties, extend any gratuity or special favor to
employees of the other Party.
59
ARTICLE XXIV: CAPTIONS
SECTION 24.1 Captions
All indices, titles, subject headings, section titles and similar items
in this Agreement are provided for the purpose of reference and convenience only
and are not intended to be inclusive, definitive or to affect the meaning of the
contents or scope of this Agreement.
ARTICLE XXV: CHOICE OF LAWS
SECTION 25.1 Choice of Laws
(a) This Agreement shall be governed by, and construed in accordance
with, the law of the State of New York, exclusive of conflicts of laws
provisions.
(b) Each of the Parties hereby submits for itself and its property to
the exclusive jurisdiction of the courts of the State of New York, the courts of
the United States for the Southern District of New York, and appellate courts
from any thereof for the purposes of all legal proceedings arising out of or
relating to this Agreement, the transactions contemplated by this Agreement, or
for recognition and enforcement of any judgment in respect thereof. Each Party
consents and agrees that any such action or proceeding may be brought in and
only in such courts and irrevocably waives, to the fullest extent permitted by
applicable law, any objection which it may now or hereafter have to the laying
of the venue of any such proceeding brought in such a court and any claim that
any such proceeding brought in such a court has been brought in an inconvenient
forum and agrees not to plead or claim the same.
(c) Each Party agrees that service of process in any such action or
proceeding may be effected by mailing a copy thereof by registered or certified
mail (or any substantially similar form of mail), postage prepaid, to the other
party at its address set forth in Section 22.1, or at such other address of
which the other party shall have been notified pursuant thereto.
(d) Each Party hereby agrees that nothing herein shall affect the right
to effect service of process in any other manner permitted by law.
(e) Each Party hereby irrevocably waives, to the fullest extent
permitted by applicable law, any and all right to trial by jury in any legal
proceeding arising out of or relating to this agreement or the transactions
contemplated by this Agreement.
60
ARTICLE XXVI: MISCELLANEOUS PROVISIONS
SECTION 26.1 Access and Confidentiality
(a) During the Term of this Agreement hereof and consistent with this
Agreement, Seller shall provide, upon reasonable advance notice, Xxxxxxxx'
employees and/or agents reasonably acceptable to Seller continuing and
unrestricted access to the Facility, the Site, the Interconnection Facilities
(on terms consistent with the Interconnection Agreement) and all other
appurtenant electrical equipment at all times and for any duration for the
purpose of (i) verifying, reviewing, and/or monitoring the operation of the
Facility, the Interconnection Facilities and all other appurtenant electrical
equipment for the purpose of determining Seller's compliance with this
Agreement; and (ii) inspecting, examining and testing such equipment and
facilities as specifically authorized under this Agreement. Xxxxxxxx' employees
and/or agents shall be subject to all reasonable rules applicable to the
Facility and the Site with respect to such matters as safety, operations and
confidentiality provided that such rules are applied in a nondiscriminatory
manner. Xxxxxxxx' employees and/or agents shall conduct themselves so as to not
hamper or impede the Facility's operations.
(b) The Parties agree that all information relating to this Agreement,
and the administration or performance hereof by the Parties, including, but not
limited to, any information and records provided to Xxxxxxxx by Seller under
this Section 26.1:
(i) shall not be used for any purposes other than as
contemplated by this Agreement and shall be kept confidential pursuant
to and in accordance with the Confidentiality Agreement attached hereto
as Appendix 2; and
(ii) except as provided in the Confidentiality Agreement,
shall neither be removed from Seller's premises nor be duplicated,
electronically recorded, or recreated in any other manner without
Seller's prior written consent, which consent shall not be unreasonably
withheld or delayed, and shall not be released to any third parties,
other than Xxxxxxxx' Affiliates, without Seller's prior written
consent, which consent shall not be unreasonably withheld or delayed.
SECTION 26.2 Survival
The provisions of Article XI, Section 13.2, Article XIV, and Section
26.1 (including the Confidentiality Agreement attached hereto as Appendix 2),
including the rights and obligations of the Parties therein provided, shall
survive the termination or expiration of this Agreement and the performance by
the Parties of their obligations hereunder.
61
SECTION 26.3 Cost Responsibility
Whether or not the transactions contemplated by this Agreement are
consummated, except as otherwise specifically provided for in this Agreement,
all costs and expenses incurred in connection with this Agreement and the
transactions contemplated hereby shall be paid by the Party incurring such
expenses.
SECTION 26.4 No Third Party Rights
This Agreement is not intended to confer upon any Person other than the
Parties hereto any rights or remedies hereunder.
SECTION 26.5 Announcements
Except as otherwise required by law or the rules of the New York Stock
Exchange, for so long as this Agreement is in effect, neither Seller nor
Xxxxxxxx shall, nor shall they permit any of their Affiliates to, issue or cause
the publication of any press release or other public announcement with respect
to any material aspect of the transactions contemplated by this Agreement the
disclosure of which could reasonably be expected to result in an adverse effect
on the competitive position of the other Party without the consent of the other
Party, which consent shall not be unreasonably withheld or delayed.
SECTION 26.6 Support of Financing
Xxxxxxxx shall use its commercially reasonable efforts to assist Seller
in achieving the closing of financing for the Facility by Seller, including the
execution of a consent in favor of the Lenders of Seller's collateral assignment
to such Lenders of this Agreement, such consent to be mutually agreed to by
Xxxxxxxx, Seller and the Lenders.
SECTION 26.7 Right to Purchase Facility
Seller shall use its commercially reasonable efforts to include in its
financing documents a provision granting Xxxxxxxx the initial right to purchase
the Facility from the holders of Seller's debt for an amount equal to the
greater of (i) the Fair Market Value of the Facility and (ii) all amounts then
due and owing to such debt holders under Seller's financing documents, in the
event that such debt holders declare an event of default and accelerate amounts
due under Seller's financing documents as a result of an event of default under
such documents that is not caused by a default by Xxxxxxxx under this Agreement.
SECTION 26.8 Assignment of Third Party Agreements
Seller shall assign to Xxxxxxxx all rights, interests, benefits, duties
and liabilities associated with any agreement executed between Seller and any
other Person in which Seller is compensated for products produced by the
facility that prevent Seller from
62
providing Xxxxxxxx with the Net Electric Energy, Ancillary Services or Facility
Capacity to which Xxxxxxxx is entitled under this Agreement. To the extent such
assignment is not permitted by law, Seller will maintain for Xxxxxxxx the value
of this Agreement absent such other agreement.
SECTION 26.9 Examination of Records
Each party shall have the right, upon reasonable notice, at its sole
expense and during normal working hours, to examine and copy the records of the
other party to the extent reasonably necessary to verify the accuracy of any
statement, charge or computation made hereunder. If any such examination reveals
any inaccuracy in any statement, the necessary adjustments in such statement and
the payments thereof will be promptly made. This Section 26.8 will survive
termination of the Agreement or any transaction hereunder for a period of two
(2) years following the end of the calendar year in which such termination
occurs.
SECTION 26.10 Successors and Assigns
This Agreement shall inure to the benefit of and be binding upon
Xxxxxxxx and Seller and to the extent permitted hereunder, their respective
successors and assigns.
SECTION 26.11 Counterparts
This Agreement may be executed in separate counterparts by the Parties
hereto, each of which when so executed and delivered shall be an original, but
all of which shall constitute one and the same instrument.
SECTION 26.12 Entire Agreement
This Agreement, including all appendices hereto, constitutes the entire
agreement between the Parties hereto with respect to the matters contained
herein, and all prior agreements with respect to the matters covered herein are
superseded, and each Party confirms that it is not relying upon any
representations or warranties of the other Party, except as specifically set
forth herein or incorporated by reference hereto.
SECTION 26.13 Severability
Should any provision of this Agreement be held to be invalid or
unenforceable, such provision shall be invalid or unenforceable only to the
extent of such invalidity or unenforceability without invalidating or rendering
unenforceable any other provision hereof.
SECTION 26.14 Modification in Writing
This Agreement may not be amended or modified except by a written
instrument signed by each of the Parties hereto.
63
SECTION 26.15 Emissions Allowances
The Parties agree to negotiate in good faith the issue of emission
allowance management (i.e. NO(x) allowances) no later than [*] prior to the
Commercial Operation Date.
SECTION 26.16 Xxxxxxxx' Right to Intertie
Xxxxxxxx shall have the right, consistent with the design and operating
limitations of the Facility and the provisions of the Interconnection Agreement,
at Xxxxxxxx' sole cost and expense, to intertie bus bar 1 (two (2) gas turbines
and one (1) station auxiliary) to bus bar 2 (one (1) gas turbine, one (1) steam
turbine and one (1) station auxiliary); provided that this option shall not have
a negative impact on Seller's ability to perform under this Agreement
[Remainder of this page intentionally left blank.]
64
IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be
executed by their duly authorized representatives as of the date first set forth
above.
AES RED OAK, L.L.C.
By: /s/ Xxxxxxx Xxxxxx
________________________________________
Name: Xxxxxxx Xxxxxx
Title: Vice President
XXXXXXXX ENERGY MARKETING &
TRADING COMPANY
By: /s/ Xxxxxx X. Xxxxxx
________________________________________
Name: Xxxxxx X. Xxxxxx
Title: Vice President
65
APPENDIX 1
PRICING
TABLE OF CONTENTS
-----------------
PAGE
----
I. Pricing Terms.....................................................................................1-1
II. Monthly Pricing Provisions........................................................................1-1
A. Payments and Credits........................................................................1-1
1. Variable Operations & Maintenance Payment.............................................1-1
2. Total Fixed Payment...................................................................1-2
3. Energy Exercise Fee..................................................................1-3
4. Gross Domestic Product Implicit Price Deflator
(GDPIPD) Adjustment..................................................................1-4
B. Fuel Conversion Volume Rebate...............................................................1-5
III. Facility Heat Rate Bonus or Penalty...............................................................1-6
A. Facility Heat Rate..........................................................................1-6
B. Heat Rate Bonus or Penalty..................................................................1-7
IV. Availability Adjustments..........................................................................1-8
A. Calculation of Equivalent Availability Factor...............................................1-8
1. Period Availability..................................................................1-8
2. Monthly Availability.................................................................1-9
B. Period Availability Adjustment.............................................................1-10
C. Period Availability Credit.................................................................1-11
V. Non-Dispatch Payments............................................................................1-13
APPENDIX 1
PRICING
This Appendix is intended to implement certain provisions of the Agreement. All
calculations will be performed with the proper units. Capitalized terms used in
this Appendix and not defined herein shall have the meanings given such terms in
the Agreement.
I. PRICING TERMS
Xxxxxxxx shall pay Seller for Fuel Conversion Services,
Temperature Adjusted Unforced Capacity, and Ancillary Services in
accordance with the terms and conditions set forth in this Appendix and
the Agreement.
In the event the Reliability Assurance Agreement is amended to
eliminate the Capacity Resource requirement imposed as of the date
hereof on Load Serving Entities and such a requirement is not otherwise
imposed within the PJM control area so that there is no longer an
independent market for Unforced Capacity, the Parties agree to
negotiate in good faith any amendments necessary to this Agreement for
the Parties to maintain, to the extent possible, the original value of
this Agreement to both of them; provided, however, that Seller shall be
under no obligation to agree to any change to this Agreement that
adversely affects its ability to repay the Lenders.
II. MONTHLY PRICING PROVISIONS
A. PAYMENTS AND CREDITS
For each Billing Month "M" of the Term of the
Agreement commencing with the Commercial Operation Date,
Xxxxxxxx shall make payments to Seller. [*] in accordance
with the procedures set forth in Sections II.A.1, II.A.2, and
II.A.3 below.
1. VARIABLE OPERATIONS & MAINTENANCE PAYMENT
The Variable Operations & Maintenance Payment
("VOMP") for each Billing Month "M" shall be
calculated as:
[*]
where
1-1
NEE(M) = [*]
VOM(n) = [*]
2. TOTAL FIXED PAYMENT
The Total Fixed Payment ("TFP(M)") for each Billing
Month "M" shall be made by Xxxxxxxx to the Seller and
calculated as follows:
[*]
[*]
where,
UCR(n) = [*]
TAUC(M) = [*]
FCODC(M) = [*]
MUC(M) = [*]
FC(M) = [*]
[*]
FC(H) = [*]
Hours(M) = [*]
1-2
TABLE I
FUEL CONVERSION OPTION DEMAND CHARGE
------------------------------ -----------------------------------
FUEL CONVERSION OPTION DEMAND
Month CHARGE
(IN $/KW-MONTH)
------------------------------ -----------------------------------
JANUARY [*]
------------------------------ -----------------------------------
FEBRUARY [*]
------------------------------ -----------------------------------
MARCH [*]
------------------------------ -----------------------------------
APRIL [*]
------------------------------ -----------------------------------
MAY [*]
------------------------------ -----------------------------------
JUNE [*]
------------------------------ -----------------------------------
JULY [*]
------------------------------ -----------------------------------
AUGUST [*]
------------------------------ -----------------------------------
SEPTEMBER [*]
------------------------------ -----------------------------------
OCTOBER [*]
------------------------------ -----------------------------------
NOVEMBER [*]
------------------------------ -----------------------------------
DECEMBER [*]
------------------------------ -----------------------------------
3. ENERGY EXERCISE FEE
An Energy Exercise Fee ("EEF(M)") for each Unit for each Billing Month
"M" shall be made by Xxxxxxxx to Seller to compensate Seller for each
Successful Start-Up in accordance with the following:
[*]
where the above summation is over all Unit Successful Start-Ups during
Billing Month "M" and where start-up equivalent operating hours
("SEOH") are calculated as:
[*]
[*]
[*]
[*]
1-3
UISO(M) = [*]
VOM(n) = [*]
Seller shall identify which Unit was started and maintain a current
count of cumulative Successful Start-Ups and associated Shutdowns per
Unit.
Natural gas volumes for hot, warm, and cold Successful Start-Ups and
associated Shutdowns are to be based on the engineering, procurement,
and construction contractor's guidelines as stated in Appendix 9 for
the first two Contract Years. For Contract Years 3-20, required fuel
volumes to be provided by Xxxxxxxx for each of hot, warm and cold
Successful Start-Ups and associated Shutdowns will be calculated [*]
4. GROSS DOMESTIC PRODUCT IMPLICIT PRICE DEFLATOR (GDPIPD) ADJUSTMENT
The GDPIPD for a subject Contract Year (year "n" in this example) is
computed as the [*].
[*]
In the event that the publication of the Gross Domestic Product
Implicit Price Deflator is discontinued, the Parties agree to use a mutually
acceptable substitute index that represents a similar measure of general U.S.
inflation.
1-4
B. FUEL CONVERSION VOLUME REBATE
Where the Facility has achieved a Utilization Factor ("UF") of
greater than or equal to [*] of the Facility available hours for the
Rolling Twelve Month Period, Xxxxxxxx shall be entitled to a Fuel
Conversion Volume Rebate ("FCVR") of [*]. The FCVR amount shall be
determined monthly following each Rolling Twelve Month Period. [*]
where,
[*]
where,
Hours(p) = [*]
Dispatch Hours(p) = [*]
EAF(p) = [*]
PMH(p) = [*]
TAFC(p) = [*]
[*]
where,
[*]
[*]
1-5
[*]
where,
[*]
where,
TAFC(M)=[*]
[*]
EAF(M) = [*]
VOM(n) = [*]
VOMP(M) = [*]
TAFC(H) = [*]
III. FACILITY HEAT RATE BONUS OR PENALTY
A. FACILITY HEAT RATE
A Facility Heat Rate ("FHR") calculation per kWh (in HHV)
shall be made for each Dispatch Period "D" of each Billing Month "M"
based upon (a) total Natural Gas consumed during Dispatch Periods, and
(b) total Net Electric Energy delivered from the Facility during
Dispatch Periods.
where,
[*]
where,
NGBTU(D)=[*]
1-6
NEEG(D) = [*]
During periods of operation, Seller shall maintain an operating log, or
some other suitable and auditable tracking system which shall track the
amount of Natural Gas consumed in each hour of a Start-Up, Shutdown,
Dispatch Period at full load, or Dispatch Period at lower loads along
with the average load for each hour of the Dispatch Period. The
operating log shall indicate whether the Facility was engaged in a
Start-Up, Shutdown, Dispatch Period at full load, or Dispatch Period at
lower loads along with the average load for each hour of the Dispatch
Period.
B. HEAT RATE BONUS OR PENALTY
A monthly Heat Rate Bonus or Penalty ("HRB" or "HRP") will be
determined by summing HRB and HRP for each Dispatch Period "D" of each
Billing Month. Any HRB shall be paid by Xxxxxxxx to Seller. Any HRP
shall be paid by Seller to Xxxxxxxx.
[*]
The HRB or HRP will be calculated as the sum of the benefit or penalty
for each Dispatch Period "D" of Billing Month "M":
HRB(M) = [*]
HRP(M) = [*]
where
NEEG(D) = [*]
SF(D) = [*]
[*]
[*]
1-7
HRT(D) = [*]
IV. AVAILABILITY ADJUSTMENTS
A. CALCULATION OF EQUIVALENT AVAILABILITY FACTOR
1. PERIOD AVAILABILITY
An Equivalent Availability Factor ("EAF") for the Facility
will be calculated for each Period "p," including the Summer Peak
Period, the Winter Peak Period, the Rolling Twelve Month Period and the
Non-Peak Period as follows:
[*]
where
FAM(p) = [*]
[*]
sum(p) AC(H) = [*]
1-8
[*]
TAFC(p) = [*]
[*]
PMH(p) = [*]
EASOH(p) = [*]
Hours(p) = [*]
2. MONTHLY AVAILABILITY
An Equivalent Availability Factor for the Facility will be
calculated for each Billing Month "EAF(M)" in a manner similar to that
as described in Section IV.A.1, herein, with the various components of
the of the formulas measured for Billing Month "M" rather than Period
"p."
1-9
B. PERIOD AVAILABILITY ADJUSTMENT
Following the Commercial Operation Date, a Period Availability
Adjustment ("PAA") will be calculated for each Summer Peak Period,
Winter Peak Period, and Non-Peak Period when the Equivalent
Availability Factor for the corresponding Period equals or exceeds [*].
The calculation of PAA is to be made and payment, if any, is to be
given to Seller in the first Billing Month after the end of the Period.
The Period Availability Adjustment will be based on the product of the
Benefit Factors ("BF(p)") and the Availability Benefit ("AB(A)")
associated with all available hours during Period "p."
[*]
[*]
where, for the Equivalent Availability Factor for a Period,
the Benefit Factor is:
[*]
1-10
where,
AB(A) = [*]
[*]
where,
Electric Index(A) = [*]
Gas Price(A) = [*]
HRT(A) = [*]
VOM(A) = [*]
TAFC(A) = [*]
[*]
TAFC(p) = [*]
[*]
C. PERIOD AVAILABILITY CREDIT
Following the Commercial Operation Date, a Period Availability
Credit ("PAC") will be calculated for each Summer Peak Period, Winter
Peak Period and a Non-Peak Period. The Period Availability Credit will
be the product of (i) the Period Factors ("PF") for either the Summer
Peak Period, Winter Peak Period or the Non-Peak Period and (2) the Fuel
Conversion Option Demand Payments ("FCODP"):
1-11
[*]
where,
FCODP(p) = [*]
[*]
[*]
[*]
[*]
The PF(p) for the Summer Peak Period or the
Winter Peak Period in Contract Years 2 - 20
based on the applicable EAF(p) =
[*]
[*]
[*]
[*]
The PF(p) for the Non-Peak Period in
Contract Years 2 - 20 based on the
applicable EAF(p) =
[*]
1-12
[*]
[*]
[*]
The calculation of PAC(p) is to be made and credit, if any, is
to be given to Xxxxxxxx in the first Billing Month after the end of a
Period.
V. NON-DISPATCH PAYMENTS
[*]
[*]
"Replacement Price"
[*]
1-13
APPENDIX 2
CONFIDENTIALITY AGREEMENT
THIS CONFIDENTIALITY AGREEMENT (this AGREEMENT"), dated as of
____________ 1999, by and between AES Red Oak, L.L.C., a Delaware limited
liability company ("SELLER"), and Xxxxxxxx Energy Marketing & Trading Company, a
corporation organized and existing under the laws of the State of Delaware
("XXXXXXXX"), (Seller and Xxxxxxxx hereinafter referred to individually as a
"Party" and collectively as the "Parties").
RECITALS
WHEREAS, the Parties are entering into a Fuel Conversion Services,
Capacity and Ancillary Services Purchase Agreement (the "Fuel Conversion
Services Agreement"), dated as of the date hereof, pursuant to which Xxxxxxxx
will deliver fuel to Seller's electric generating facility (the "FACILITY") and
Seller will sell and Xxxxxxxx will purchase capacity, ancillary services and
fuel conversion services from the Facility.
WHEREAS, the Parties agree that, subject to the provisions of this
Agreement, the Fuel Conversion Services Agreement is to be kept confidential.
WHEREAS, the Parties understand that, during the course of the
administration and performance of the Fuel Conversion Services Agreement, they
may wish to exchange information related to the Fuel Conversion Services
Agreement that the Party providing the information desires to keep confidential.
NOW, THEREFORE, in consideration of the mutual covenants and promises
set forth below, the Parties hereto, intending to be legally bound, hereby
covenant, promise and agree as follows:
1. CONFIDENTIAL MATERIALS. When a Party deems information that it
provides to the other Party to be confidential, the Party providing such
information shall xxxx the information in a manner to indicate that it is
considered to be confidential or, if the information is provided orally, the
Party providing the information shall clearly identify the information as being
confidential at the time it is provided and promptly confirm to the other Party
in writing that such oral information is confidential (all such information that
has been so marked or identified as confidential, including the Fuel Conversion
Services Agreement, being "CONFIDENTIAL MATERIAL").
Except as set forth in Section 4 below, each Party and its
Representatives (as hereinafter defined) agree to treat confidentially any
Confidential material provided to it by the other Party, together with all
notes, analyses, compilations or studies prepared by such Party or its
Representatives that contain or otherwise reflect such Confidential Material.
For purposes of this Agreement, "REPRESENTATIVES" shall mean a Party's, or its
2-1
Affiliates' (as such term is defined in the Fuel Conversion Services Agreement)
directors, officers, employees, and outside counsel, accountants and lenders.
Each Party and its Representatives shall protect the Confidential Material
against disclosure using the same degree of care, but no less than a reasonable
degree of care, as it would use to protect its own confidential information of a
like nature.
2. EXCLUDED MATERIALS. The term Confidential Material shall not include
information of the disclosing Party which (i) at the time of disclosure is
generally available to the public other than as a result of a disclosure by the
receiving Party or its Representatives, (ii) was available to the receiving
Party on a non-confidential basis prior to its receipt from the disclosing
Party, (iii) has become available to the receiving Party on a non-confidential
basis from a source other than the disclosing party or its Representatives, but
only if such source is, to the best of the receiving Party's knowledge, lawfully
entitled to make such disclosure and is not bound by a confidentiality agreement
with such disclosing Party, or (iv) which has been independently developed by
the receiving Party or its Representatives without violation of this Agreement.
3. DISCLOSURE TO REPRESENTATIVES. Each Party may disclose the
Confidential Material to those of its Representatives who require such material
for the purpose of administering or performing the Fuel Conversion Services
Agreement or developing, constructing, financing or operating the Facility,
provided that, except as set forth in Section 4 below, such Representatives
agree to be bound by the terms of this Agreement. Each Party agrees that the
Confidential Material will be kept confidential by it and, except as set forth
in Section 4 below, its Representatives and, except with the specific prior
written consent of an officer of the other Party, will not be disclosed by it or
its Representatives except as permitted hereby. In any event, each Party shall
be responsible for any breach of this Agreement by it or by any of its
Representatives, and each Party shall, at its sole expense, take all reasonable
measures to restrain its Representatives from prohibited or unauthorized
disclosure or use of the Confidential Material.
4. CONFIDENTIAL TREATMENT OF FUEL CONVERSION SERVICES AGREEMENT.
Notwithstanding any other provision of this Agreement, Seller shall be permitted
to (a) include a summary of the material terms of the Fuel Conversion Services
Agreement in offering documents provided to potential purchasers and purchasers
of the Project's debt (collectively, "OFFEREES") pursuant to Rule 144A under the
Securities Act of 1933, as amended (together with any similar rule or
regulation, "RULE 144A"), and (b) make available to such Offerees for their
review copies of the Fuel Conversion Services Agreement and provide to such
Offerees, upon request, copies of the Fuel Conversion Services Agreement;
PROVIDED, HOWEVER, that prior to the distribution of the summary referred to in
clause (a) above to any Rating Agency (as such term is defined in the Fuel
Conversion Services Agreement) or any Offeree, Seller shall (i) provide Xxxxxxxx
a copy thereof and Xxxxxxxx shall have a reasonable period of time to review and
provide comments thereon to Seller, (ii) give due consideration to such comments
in finalizing the summary in light of Xxxxxxxx' interest in protecting its
proprietary information and in
2-2
light of Seller's disclosure obligations under applicable securities laws, and
(iii) together with Xxxxxxxx, attempt in good faith to resolve any disagreements
concerning information to be included in such summary, and PROVIDED, FURTHER,
that Seller shall use its commercially reasonable efforts to have such Offerees
execute confidentiality agreements with respect to the Fuel Conversion Services
Agreement and shall not provide the Fuel Conversion Services Agreement to any
Offeree if such Offeree or any of its Affiliates (as such term is defined in the
Fuel Conversion Services Agreement) is a Federal Energy Regulatory Commission
("FERC") authorized power marketer or has applied for such authorization.
Xxxxxxxx also recognizes that in the event that Seller files a registration
statement with the Securities and Exchange Commission ("SEC") in respect of any
debt offering, it will be required to submit a copy of the Fuel Conversion
Services Agreement to the SEC. Seller shall use its commercially reasonable
efforts to obtain confidential treatment of the Fuel Conversion Services
Agreement by the SEC, in the event it is filed with the SEC, in accordance with
SEC rules. In the event that Seller is required to file a copy of the Fuel
Conversion Services Agreement with FERC, Seller shall use its commercially
reasonable efforts to seek confidential treatment by FERC, in accordance with
FERC's rules, of those portions of the Fuel Conversion Services Agreement for
which Xxxxxxxx requests such confidential treatment.
5. DEFENSE OF CONFIDENTIALITY. In the event that a Party or any of its
Representatives is requested or required in any legal proceeding (deposition,
interrogatory, request for documents, subpoena, civil investigation demand or
similar process) to disclose any of the Confidential Material, it is agreed that
such Party will provide the other Party with prompt notice of such request(s) so
that the other Party may seek an appropriate protective order or other
appropriate remedy and/or waive compliance with the provisions of this
Agreement. In the event that such protective order or other remedy is not
obtained, or a waiver is not granted hereunder, only that portion of the
Confidential Material which, in the written opinion of counsel for the
disclosing Party, is legally compelled to be disclosed shall be disclosed
without liability hereunder and such Party will exercise its best efforts to
obtain reliable assurance that confidential treatment will be accorded any
Confidential material so furnished.
6. RETURN OF CONFIDENTIAL MATERIALS. Upon the written request of a
Party, the other Party and its Representatives will promptly deliver to the
requesting Party all Confidential Material (other than the Fuel Conversion
Services Agreement) received from that Party in written and/or tangible form,
including copies, reproductions or written materials containing confidential
Material. In the event of such request, all other notes, analyses, compilations
or studies constituting Confidential Material in the possession of the other
Party or its Representatives will be destroyed, with any such destruction
certified by in writing; provided that a Party shall be entitled to retain one
(1) copy of all Confidential Material, subject to the confidentiality
requirements of this Agreement and under the control of the office of the
General Counsel of such Party.
7. INDEMNITY. Each Party hereby agrees to indemnify and hold harmless
the other Party from any damage, loss, cost or liability (including reasonable
legal fees
2-3
and the cost of enforcing this indemnity) arising out of or resulting from any
use or disclosure by a Party or its Representatives of the Confidential Material
not authorized under this Agreement. The Parties acknowledge the representations
of the other Party that the Confidential Material is of a special, unique,
unusual and extraordinary character and agree that money damages would be an
insufficient remedy for any breach of this Agreement and that any such breach
would cause irreparable harm. Accordingly, the Parties also agree that in the
event of any breach or threatened breach of this Agreement, the injured Party,
in addition to any other remedies it may have at law or in equity, shall be
entitled, without the requirement of posting a bond or any other security, to
equitable relief, including injunctive relief and specific performance against
the other Party or its Representatives.
8. NO WAIVER. It is understood and agreed that no failure or delay by a
Party in exercising any right, power or privilege hereunder shall operate as a
waiver thereof, nor shall any single or partial exercise thereof preclude any
other or further exercise thereof or the exercise of any right, power or
privilege hereunder.
9. EFFECTIVE DATE AND TERM. This Agreement shall be effective as of
the date first written above, and shall remain in effect for a period of [*]
after the expiration, termination or cancellation of the Fuel Conversion
Services Agreement.
10. SEVERABILITY. If any provision of this Agreement shall be held or
deemed to be or shall, in fact, be illegal, inoperative or unenforceable, the
same shall not affect any other provision or provisions herein contained or
render the same invalid, inoperative or unenforceable to any extent whatsoever.
11. AMENDMENT. The terms and conditions set forth in this Agreement may
be modified or waived only by a written instrument executed by a duly authorized
officer of each of the Parties hereto. In addition, this Agreement shall be
binding upon and inure to the benefit of the Parties hereto and their respective
successors and permitted assigns.
12. NOTICES. Any notice, request, consent, waiver or other
communication required or permitted hereunder shall be effective only if it is
in writing and personally delivered or sent by certified or registered mail,
postage prepaid, or by nationally recognized overnight courier, addressed as set
forth below:
If to Xxxxxxxx:
Xxxxxxxx Energy Marketing & Trading Company
Xxx Xxxxxxxx Xxxxxx
Xxxxx, XX 00000
Attention: Contract Management
Facsimile: 000-000-0000
If to Seller:
2-4
AES Red Oak, L.L.C.
0000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000
Attention: General Counsel
Telephone: (000) 000-0000
Facsimile: (000) 000-0000
or to such other person or address as the addressee may have specified in a
notice duly given to the sender as provided herein. Such notice or communication
shall be deemed to have been given as of the date received by the recipient
thereof.
13. GOVERNING LAW. This Agreement shall be governed by and construed
and interpreted in accordance with the laws of the State of New York, without
regard to any conflict of laws provisions of such laws.
14. COUNTERPARTS. This Agreement may be executed in any number of
counterparts, each of which shall be deemed to be an original, but all of which
together shall constitute one and the same instrument.
15. ENTIRE AGREEMENT. This Agreement constitutes the entire agreement
of the Parties with respect to the matters contained herein and all prior
agreements of the Parties with respect to the matters contained herein are
superseded.
IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be
executed by their duly authorized representatives as of the date first set forth
above.
AES RED OAK, L.L.C.
By: /s/ Xxxxxxx Xxxxxx
---------------------------------
Name: Xxxxxxx Xxxxxx
Title: Vice President
XXXXXXXX ENERGY MARKETING & TRADING
COMPANY
By: /s/ Xxxxxx X. Xxxxxx
----------------------------------
Name: Xxxxxx X. Xxxxxx
Title: Vice President
2-5
APPENDIX 3
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
EXEMPT WHOLESALE GENERATOR CERTIFICATION
[To be provided by Seller as soon as reasonably
practicable after the Execution Date
but in no event later than the Commercial Operation Date]
APPENDIX 4.A.
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
PRELIMINARY SINGLE-LINE DIAGRAM
SHOWING NATURAL GAS DELIVERY POINTS
[To be provided by Xxxxxxxx as soon as reasonably
practicable after the Execution Date
but in no event later than the Commercial Operation Date]
APPENDIX 4.B.
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
PRELIMINARY SINGLE-LINE DIAGRAM
SHOWING ELECTRIC DELIVERY
[To be supplied after Execution Date]
APPENDIX 5
GUARANTY BY
THE AES CORPORATION
GUARANTY (this "GUARANTY"), dated as of [ ], by The AES
Corporation, a Delaware corporation (the "GUARANTOR"), in favor of Xxxxxxxx
Energy Marketing & Trading Company, a Delaware corporation ("GUARANTEED
PARTY"), pursuant to Section 18.2 of that certain Fuel Conversion Services,
Capacity and Ancillary Services Agreement, dated as of [ ], by and
between Guaranteed Party and AES Red Oak, L.L.C., a Delaware limited liability
company (the "COMPANY"), as modified or supplemented from time to time (the
"AGREEMENT").
RECITALS
WHEREAS, Guaranteed Party has agreed to enter into the Agreement in
reliance upon the Guarantor's agreement, pursuant to the terms and conditions
set forth below, to provide this Guaranty to Guaranteed Party; and
WHEREAS, Guarantor is willing to provide this Guaranty to Guaranteed
Party, on the terms and conditions set forth below, as an inducement to
Guaranteed Party to enter into the Agreement with the Company.
NOW, THEREFORE, in consideration of the above premises and for other
good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, and intending to be bound hereby, the Guarantor agrees as follows:
1. OBLIGATIONS OF GUARANTOR. Subject to the Guaranty Cap set forth in
Section 2 of this Guaranty, the Guarantor unconditionally and irrevocably
guaranties, as primary obligor and not merely as surety, to and for the benefit
of Guaranteed Party, prompt and complete payment of all damage amounts due and
payable to Guaranteed Party by the Company under and pursuant to Section 18.1 of
the Agreement, together with any and all reasonable expenses (including
reasonable attorneys' fees and expenses) incurred by Guaranteed Party in
enforcing this Guaranty, (collectively, the "OBLIGATIONS"). Subject to the
Guaranty Cap set forth in Section 2 of this Guaranty, the Guarantor agrees, that
upon the failure of the Company to pay any of the Obligations when they become
due, the Guarantor will pay, or cause to be paid, to Guaranteed Party any and
all such unpaid Obligations.
2. MAXIMUM GUARANTEED AMOUNT. The aggregate liability of the Guarantor
under this Guaranty and Guaranteed Party's right to recovery hereunder is
limited to a total aggregate amount of [*] (the "GUARANTY CAP").
5-1
3. NATURE OF OBLIGATIONS. The Guarantor guaranties that the Obligations
shall be paid strictly in accordance with the terms of the Agreement, regardless
of any law, regulation or order now or hereafter in effect in any jurisdiction
affecting any of such terms or the rights of Guaranteed Party with respect
thereto. The duties of the Guarantor under this Guaranty are independent of the
Obligations, and a separate action or actions may be brought and prosecuted
against the Guarantor to enforce this Guaranty, irrespective of whether any
action is brought against the Company or whether the Company is joined in any
such action or actions. Guaranteed Party shall not be obligated to file any
claim relating to the obligations if the Company becomes subject to a
bankruptcy, reorganization or similar proceeding and neither the failure of
Guaranteed Party to so file, nor the existence of any such proceeding, shall
affect the Guarantor's obligations hereunder. The liability of the Guarantor
under this Guaranty as specified in Section 1 of this Guaranty shall, to the
fullest extent permitted by law, be absolute and unconditional irrespective of:
(i) any change in the time, manner or place of payment of, or
in any other term of, all or any of the Obligations, or any other
amendment or waiver of or any consent to departure from the Agreement,
including, without limitation, any increase in the Obligations;
provided, however, no action taken pursuant to this Section 3(i) shall
be construed to extend the term of this Guaranty or increase the amount
of the Guaranty Cap;
(ii) any manner of sale or other disposition of assets of the
Company or any of its Affiliates (as such term is defined in the
Agreement); or
(iii) any change, restructuring or termination of the
structure or existence of the Company or any of its Affiliates.
The Guarantor shall not contest the amount, Guaranteed Party's right to
collect, or Guaranteed Party's collection of, the Obligations (as they may be
revised from time to time as provided for herein) in any future proceeding
including, without limitation, civil, criminal, regulatory, administrative,
judicial, equitable, or appellate, on the basis that the Obligations constitute
a penalty, are or will result in a forfeiture, or are otherwise unlawful;
provided, however that, notwithstanding anything to the contrary contained
herein, the Guarantor may assert that Guaranteed Party's actual damages are less
than the Obligations, contest liability or assert any other claim or defense
that the Company could assert, except as expressly limited herein, so long as
the Guarantor does not duplicate or reassert any claims or initiate any
proceedings that were resolved or concluded previously by the Company.
The Guarantor agrees that the obligations of the Guarantor set forth in
this Guaranty shall be direct obligations of the Guarantor, and such obligations
shall be absolute and unconditional and shall not be subject to any
counterclaim, set-off,
5-2
deduction, diminution, abatement, recoupment, suspension, deferment, reduction
or defense (other than full and strict compliance by the Guarantor with its
obligations hereunder) based upon any claim the Guarantor or any other Person
(as such term is defined in the Agreement) may have against Guaranteed Party or
the Company. This Guaranty shall continue to be effective or be reinstated, as
the case may be, if at any time any payment of any of the Obligations is
rescinded or must otherwise be returned upon the insolvency, bankruptcy or
reorganization of the Company or otherwise, all as though such payment had not
been made.
4. WAIVER. The Guarantor hereby waives demand, promptness, diligence,
presentment, notice of acceptance, notice of protest for non-payment and any
other notice or similar action with respect to any of the Obligations and this
Guaranty and any requirement that Guaranteed Party exhaust any right or take any
action against the Company or any other Person.
5. SUBROGATION. The Guarantor shall not exercise any rights which it
may acquire by way of subrogation under this Guaranty, by any payment made
hereunder or otherwise, until all Obligations and all other amounts payable
under this Guaranty shall have been paid in full to Guaranteed Party. If any
amount shall be paid to the Guarantor on account of any subrogation rights at
any time prior to the payment in full of the Obligations and all other amounts
payable under this Guaranty, such amount(s) shall be paid immediately to
Guaranteed Party to be credited and applied to the Obligations, whether matured
or unmatured, in accordance with the terms hereof and the Agreement. Upon full
payment of the Obligations and all other amounts payable under this Guaranty,
Guarantor shall be subrogated to the rights of Guaranteed Party, and Guaranteed
Party shall take all such reasonable actions, at the Guarantor's sole expense,
as Guarantor shall reasonably request to effect such subrogation rights.
6. CERTAIN RIGHTS AND POWERS OF GUARANTEED PARTY. Guaranteed Party
shall have all of the rights and remedies available under applicable law and may
proceed by appropriate court action to enforce the terms hereof and to recover
damages for the breach hereof. Each and every remedy of Guaranteed Party shall,
to the extent permitted by law, be cumulative and shall be in addition to any
other remedy now or hereafter existing at law or in equity. At the option of
Guaranteed Party and upon notice to the Guarantor, the Guarantor may be joined
in any action or proceeding commenced by Guaranteed Party against the Company in
respect of any Obligation, and recovery may be had against the Guarantor in such
action or proceeding or in any independent action or proceeding against the
Guarantor, without any requirement that Guaranteed Party first assert, prosecute
or exhaust any remedy or claim against the Company.
7. REPRESENTATIONS AND WARRANTIES. The Guarantor represents and
warrants to Guaranteed Party as follows:
5-3
(a) ORGANIZATION AND GOOD STANDING. The guarantor is a corporation duly
organized, validly existing and in good standing under the laws of the State of
Delaware and each jurisdiction in which it currently conducts its business. The
Guarantor has all requisite corporate power and authority to carry on its
business as it is now conducted and as contemplated by this Guaranty, and to
enter into and perform its obligations hereunder.
(b) DUE AUTHORIZATION; NO CONFLICTS. The execution, delivery and
performance by the Guarantor of the Guaranty has been duly and effectively
authorized by all necessary corporate action of the Guarantor. No other
corporate proceedings are necessary to authorize the execution and delivery by
the Guarantor of this Guaranty; and this Guaranty is the valid and binding
obligation of Guarantor, enforceable in accordance with its terms, except as
such enforceability may be limited by applicable bankruptcy, insolvency or
similar laws from time to time in effect that affect creditors' rights generally
or by general principles of equity. Neither the execution and delivery of this
Guaranty nor compliance by the Guarantor with any of the provisions hereof will
(i) violate, or conflict with, or result in a breach of any provisions of, or
constitute a default (or an event which, with notice or lapse of time or both,
would constitute a default) under, or result in the termination of, or
accelerate the performance required by, or result in the creation of any lien
upon any of the properties or assets of the Guarantor under any of the terms,
conditions or provisions of the Certificate of Incorporation or By-Laws of the
Guarantor in effect on the date of this Guaranty (hereinafter, the "EFFECTIVE
DATE") or any agreement or other instrument or obligation to which the Guarantor
is a party at the Effective Date, or by which the Guarantor or any of its
properties or assets or may be bound or affected as of the Effective Date, or
(ii) violate any order, writ, injunction decree, arbitration award, statute,
rule or regulation applicable at the Effective Date to the Guarantor or any of
its properties or assets.
(c) NO CONSENT REQUIRED. No permit, authorization, consent, approval,
waiver, exception, variance, ruling, order decree, exemption, filing, recording,
registration, notice or declaration (collectively, "Governmental Approval"), is
required or to be made on the Guarantor's behalf with any federal, state,
county, municipal, regional, local, territorial or other governmental
department, regulatory body, commission, board, bureau, agency, taxing authority
or other instrumentality (collectively, "GOVERNMENTAL AUTHORITY") to authorize
the execution and delivery of this Guaranty or the taking of any future action
contemplated hereby, except for those Governmental Approvals (i) which have
already been obtained or (ii) the failure of which to obtain would not have an
adverse effect on the ability of the Guarantor to perform and satisfy its
obligations hereunder.
(d) NO DEFAULT UNDER OTHER AGREEMENTS. The guarantor is not in default,
and no condition exists that with notice or lapse of time or both would
constitute a default, under any mortgage, deed of trust, indenture or other
instrument or agreement to which it is a party or by which it or any of its
properties or assets may be bound, that would have a material adverse effect on
the Guarantor's ability to perform under this Guaranty; and the Guarantor is not
in violation of any federal, state, or local rules, ordinances, judgments,
5-4
decrees, injunctions, writs, interpretations, licenses and permits or orders of
any court, arbitrator (collectively, "REQUIREMENTS OF LAW"), or Governmental
Authority that could have a material adverse effect on the Guarantor's ability
to perform under this Guaranty.
(e) LITIGATION. There is no litigation, proceeding, arbitration or
government investigation pending or, so far as known to the Guarantor,
threatened with respect to or otherwise relating to the Guarantor which if
adversely determined could, in any one case or in the aggregate, have a material
adverse effect on the ability of the Guarantor to comply with its obligations
under this Guaranty.
(f) COMPLIANCE WITH LAW. (i) The Guarantor has complied in all material
respects with all Requirements of Law relating to this Guaranty, the Guarantor
has received no written notice to the effect that, or otherwise been advised in
writing that, it is not in compliance with any requirement of law or
governmental approval relating to this Guaranty, and the Guarantor has no reason
to believe that any currently existing circumstances are likely to result in
violations by the Guarantor of any such requirement of law which could in any
one case or in the aggregate, have a material adverse effect on the ability of
the Guarantor to perform under this Guaranty; and (ii) to the best of the
knowledge of the Guarantor, there is not now pending any proceeding, hearing or
investigation with respect to the adoption of amendments or modifications to any
existing requirement of law or governmental approval with respect to such
matters which, if adopted, would have a material adverse effect on the ability
of the Guarantor to comply with its obligations under the Guaranty.
8. COVENANTS. The Guarantor covenants and agrees that, so long as any
part of the Obligations shall remain unpaid, the Guarantor shall:
(a) PERFORMANCE AND COMPLIANCE WITH OTHER AGREEMENTS. Perform and
comply with each of the material provisions of each material indenture, credit
agreement, contract or other agreement by which the Guarantor is bound,
non-performance or non-compliance with which would have a material adverse
effect on its ability to perform its obligations hereunder, except material
contracts or other agreements being contested in good faith.
(b) PRESERVATION OF CORPORATE EXISTENCE, ETC. Preserve and maintain its
corporate existence and preserve its material rights, franchises and privileges
to conduct its business substantially as conducted on the date hereof.
(c) COMPLIANCE WITH LAWS, ETC. Comply with all Requirements of Law and
Governmental Approvals, non-compliance with which would have a material adverse
effect on its ability to perform its obligations herein, except laws, rules,
regulations and orders being contested in good faith.
5-5
(d) NOTICE OF BREACH. Provide, as soon as possible and in any event
within three (3) business days after the occurrence of any default or breach of
the obligations applicable to the Guarantor hereunder, a statement of the Chief
Financial Officer or Vice-President and Treasurer of the guarantor setting forth
details of the circumstances leading to such breach or default hereof and the
action which the Guarantor proposes to take with respect thereto.
(e) MERGERS, ETC. Not merge with any person, corporation, partnership,
or other entity unless: (i) the surviving and resulting entity agrees in writing
to be bound hereby to the same extent as the Guarantor, and (ii) immediately
after giving effect thereto, no event of default or breach of this Guaranty
shall have occurred and be continuing.
9. NO WAIVER. No failure on the part of Guaranteed Party to exercise,
and no delay in exercising, any right hereunder shall operate as a waiver
thereof; nor shall any single or partial exercise of any right hereunder
preclude any other or further exercise thereof or the exercise of any other
right.
10. CONTINUING GUARANTY. This guaranty is a continuing guaranty and
shall (i) remain in full force and effect until the payment in full of all
amounts payable under this Guaranty, (ii) be binding upon the Guarantor, its
successors and assigns, and (iii) inure to the benefit of, and be enforceable
by, Guaranteed Party and its successors, transferees and assigns.
11. WAIVER OF NOTICES. The Guarantor hereby unconditionally and
irrevocably waives all notices to and demands upon Red Oak or the Guarantor and
all other formalities, the omission of any of which or delay in performance of
which, might, but for the provisions of this paragraph, by rule of law, under
equitable principles or otherwise, constitute grounds for relieving or
discharging the Guarantor in whole or in part from its obligations hereunder.
12. NO CONSEQUENTIAL DAMAGES. Neither Party shall be liable to the
other under this Guaranty or otherwise for any exemplary, consequential,
special, or punitive losses or damages that may be incurred by either Party as a
result of their execution of and performance under this Guaranty.
13. FURTHER ASSURANCES. The Guarantor, at its sole cost and expense,
shall cause to be promptly and duly taken, executed, acknowledged and delivered,
such further documents and instruments as Guaranteed Party may from time to time
reasonably request in order to carry-out more effectively the intent and
purposes of this Guaranty.
14. SEVERABILITY. If any provision of this Guaranty shall be held or
deemed to be or shall, in fact, be illegal, inoperative or unenforceable, the
same shall not affect any
5-6
other provision or provisions herein contained or render the same invalid,
inoperative or unenforceable to any extent whatsoever.
15. COUNTERPARTS; EFFECTIVENESS. This guaranty may be executed in any
number of counterparts, each of which shall be deemed to be an original, but all
of which together shall constitute one and the same instrument. The Effective
Date of this Guaranty for all purposes shall be the date on which a Notice to
Proceed is provided to AES Red Oak L.L.C. in accordance with the Agreement.
16. AMENDMENT; WAIVER; REQUIREMENT OF WRITING. This Guaranty cannot be
amended, changed, modified, released or discharged except by a writing signed by
the party against whom enforcement of the amendment, change, modification or
waiver is sought.
17. ADDRESS FOR NOTICES. Any notice, request, consent, waiver or other
communication required or permitted hereunder shall be effective only if it is
in writing and personally delivered or sent by certified or registered mail,
postage prepaid, or by nationally recognized overnight courier, addressed as set
forth below:
If to Guaranteed Party:
Xxxxxxxx Energy Marketing and Trading Company
Xxx Xxxxxxxx Xxxxxx
Xxxxx, XX 00000
Attention: Credit
Telephone: (000) 000-0000
Facsimile: (000) 000-0000
If to Guarantor:
The AES Corporation
0000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000
Attention: General Counsel
Telephone: (000) 000-0000
Facsimile: (000) 000-0000
or to such other person or address as the addressee may have specified in a
notice duly given to the sender as provided herein. Such notice or communication
shall be deemed to have been given as of the date received by the recipient
thereof.
18. GOVERNING LAW. This Guaranty shall be construed in accordance with
and governed by the laws of the State of New York, without regard to the
conflict of laws provisions of such laws.
5-7
19. SUBMISSION TO JURISDICTION. Each of Guaranteed Party and the
Guarantor hereby irrevocably and unconditionally:
(a) submits for itself and its property in any legal action or
proceeding relating to this Guaranty, or for recognition and enforcement of any
judgment in respect thereof, to the exclusive general jurisdiction of the courts
of the State of New York, the courts of the United States of the Southern
District of New York, and appellate courts with jurisdiction over any appeals
therefrom;
(b) consents and agrees that any such action or proceeding may be
brought in and only in such courts and waives any objection that it may now or
hereafter have to the venue of any such action or proceeding in any such court
or that such action or proceeding was brought in an inconvenient court and
agrees not to plead or claim the same;
(c) agrees that service of process in any such action or proceeding may
be effected by mailing a copy thereof by registered or certified mail (or any
substantially similar form of mail), postage prepaid, to its address set forth
in Section 17 of this Guaranty, or at such other address of which the other
party shall have been notified pursuant thereto; and
(d) agrees that nothing herein shall affect the right to effect service
of process in any other manner permitted by law.
20. ASSIGNMENT; TERMINATION. This Guaranty may be assigned by the
Guarantor only with the prior written consent of Guaranteed Party, which consent
shall not be unreasonably withheld. Guaranteed Party may assign this Guaranty
only as permitted under the Agreement with respect to assignments by Guaranteed
Party of its rights thereunder. This Guaranty shall be binding upon, and inure
to the benefit of, the parties hereto and their respective successors and
permitted assigns. this Guaranty shall terminate, and Guarantor shall have no
further liability or obligations hereunder on the earlier of, [*].
[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]
5-8
IN WITNESS WHEREOF, the Guarantor and Guaranteed Party have each caused
this Guaranty to be executed on its behalf by its duly authorized office as of
the date shown above.
THE AES CORPORATION
as Guarantor
By:
--------------------------------------
Name:
Title:
ACCEPTED AND ACKNOWLEDGED:
XXXXXXXX ENERGY MARKETING &
TRADING COMPANY
By:
--------------------------------------
Name:
Title:
5-9
APPENDIX 6
GUARANTY BY
THE XXXXXXXX COMPANIES, INC.
GUARANTY (this "GUARANTY"), dated as of [ ], by The Xxxxxxxx Companies,
Inc., a Delaware corporation (the "GUARANTOR"), in favor of AES Red Oak, L.L.C.,
a Delaware limited liability company ("GUARANTEED PARTY"), pursuant to Section
18.3 of that certain Fuel Conversion Services, Capacity and Ancillary Services
Agreement, dated as of [ ], by and between Guaranteed Party and Xxxxxxxx Energy
Marketing & Trading Company, a Delaware corporation and a subsidiary of
Guarantor (the "COMPANY"), as modified or supplemented from time to time (the
"AGREEMENT").
RECITALS
WHEREAS, Guaranteed Party has agreed to enter into the Agreement in
reliance upon the Guarantor's agreement, pursuant to the terms and conditions
set forth below, to provide this Guaranty to Guaranteed Party; and
WHEREAS, Guarantor is willing to provide this Guaranty to Guaranteed
Party, on the terms and conditions set forth below, as an inducement to
Guaranteed Party to enter into the Agreement with the Company.
NOW, THEREFORE, in consideration of the above premises and for other
good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, and intending to be bound hereby, the Guarantor agrees as follows:
1. OBLIGATIONS OF GUARANTOR. Subject to the Guaranty Cap set forth in
Section 2 of this Guaranty, the Guarantor unconditionally and irrevocably
guaranties, as primary obligor and not merely as surety, to and for the benefit
of Guaranteed Party, the prompt payment and performance when due of all present
and future obligations (i) of the Company to make Fixed Payments pursuant to,
and as such term is defined in, the Agreement and (ii) to pay damages arising
under the Agreement in respect of the Company's obligation to make Total Fixed
Payments under the Agreement (including damages related to the loss of the
Company's Total Fixed Payments arising from any breach by the Company of the
Agreement or a termination of the Agreement for cause by Guaranteed Party)
together with any and all reasonable expenses (including reasonable attorneys'
fees and expenses) incurred by Guaranteed Party in enforcing this Guaranty (the
obligations referred to in clauses (i) and (ii) collectively and individually,
the "OBLIGATIONS"). Subject to the Guaranty Cap set forth in Section 2 of this
Guaranty, the Guarantor agrees, that upon the failure of the Company to pay any
of the Obligations when they become due, the Guarantor will pay, or cause to be
paid, to Guaranteed Party any and all such unpaid Obligations.
6-1
2. Maximum Guaranteed Amount.
(a) The aggregate liability of the Guarantor under this Guaranty and
Guaranteed Party's right of recovery hereunder is limited to a total aggregate
amount of [*], as reduced from time to time as provided for in the following
paragraph (the "GUARANTY CAP").
(b) [*]
3. NATURE OF OBLIGATIONS. The Guarantor guaranties that the Obligations
shall be paid strictly in accordance with the terms of the Agreement, regardless
of any law, regulation or order now or hereafter in effect in any jurisdiction
affecting any of such terms or the rights of Guaranteed Party with respect
thereto. The duties of the Guarantor under this Guaranty are independent of the
Obligations, and a separate action or actions may be brought and prosecuted
against the Guarantor to enforce the Guaranty, irrespective of whether any
action is brought against the Company or whether the Company is joined in any
such action or actions. Guaranteed Party shall not be obligated to file any
claim relating to the Obligations if the Company becomes subject to a
bankruptcy, reorganization or similar proceeding and neither the failure of
Guaranteed Party to so file, nor the existence of any such proceeding, shall
affect the Guarantor's obligations hereunder. The liability of the Guarantor
under this Guaranty as specified in Section 1 of this Guaranty shall, to the
fullest extent permitted by law, be absolute and unconditional irrespective of:
(i) any change in the time, manner or place of payment of, or
in any other term of, all or any of the Obligations, or any other
amendment or waiver of or any consent to departure from the Agreement,
including, without limitation, any increase in the Obligations;
provided, however, no action taken pursuant to this Section 3(i) shall
be construed to extend the term of this Guaranty or increase the amount
of the Guaranty Cap;
(ii) any manner of sale or other disposition of assets of the
Company or any of its Affiliates (as such term is defined in the
Agreement); or
6-2
(iii) any change, restructuring or termination of the
structure or existence of the Company or any of its Affiliates.
The Guarantor shall not contest the amount, Guaranteed Party's right to
collect, or Guaranteed Party's collection of, the Obligations (as they may be
revised from time to time as provided for herein) in any future proceeding
including, without limitation, civil, criminal, regulatory, administrative,
judicial, equitable, or appellate, on the basis that the Obligations constitute
a penalty, are or will result in a forfeiture, or are otherwise unlawful;
provided, however, that, notwithstanding anything to the contrary contained
herein, the Guarantor may assert that Guaranteed Party's actual damages are less
than the Obligations, contest liability or assert any other claim or defense
that the Company could assert, except as expressly limited herein, so long as
the Guarantor does not duplicate or reassert any claims or initiate any
proceedings that were resolved or concluded previously by the Company.
The guarantor agrees that the obligations of the Guarantor set forth in
this Guaranty shall be direct obligations of the Guarantor, and such obligations
shall be absolute and unconditional and shall not be subject to any
counterclaim, set-of, deduction, diminution, abatement, recoupment, suspension,
deferment, reduction or defense (other than full and strict compliance by the
Guarantor with its obligations hereunder) based upon any claim the Guarantor or
any other Person (as such term is defined in the Agreement) may have against
Guaranteed Party or the Company. This Guaranty shall continue to be effective or
be reinstated, as the case may be, if at any time any payment of any of the
Obligations is rescinded or must otherwise be returned upon the insolvency,
bankruptcy or reorganization of the Company or otherwise, all as though such
payment had not been made.
4. WAIVER. The Guarantor hereby waives demand, promptness, diligence,
presentment, notice of acceptance, notice of protest for non-payment and any
other notice or similar action with respect to any of the Obligations and this
Guaranty and any requirement that Guaranteed Party exhaust any right or take any
action against the Company or any other Person.
5. SUBROGATION. The Guarantor shall not exercise any rights which it
may acquire by way of subrogation under this Guaranty, by any payment made
hereunder or otherwise, until all Obligations and all other amounts payable
under this Guaranty shall have been paid in full to Guaranteed Party. If any
amount shall be paid to the Guarantor on account of any subrogation rights at
any time prior to the payment in full of the Obligations and all other amounts
payable under this Guaranty, such amount(s) shall be paid immediately to
Guaranteed Party to be credited and applied to the Obligations, whether matured
or unmatured, in accordance with the terms hereof and the Agreement. Upon full
payment of the Obligations and all other amounts payable under this Guaranty,
Guarantor shall be subrogated to the rights of Guaranteed Party, and Guaranteed
Party shall take all such reasonable actions, at the Guarantor's sole expense,
as Guarantor shall reasonably request to effect such subrogation rights.
6. CERTAIN RIGHTS AND POWERS OF GUARANTEED PARTY. Guaranteed Party
shall have all of the rights and remedies available under applicable law and may
proceed by appropriate court
6-3
action to enforce the terms hereof and to recover damages for the breach hereof.
Each and every remedy of Guaranteed Party shall, to the extend permitted by law,
be cumulative and shall be in addition to any other remedy now or hereafter
existing at law or in equity. At the option of guaranteed Party and upon notice
to the Guarantor, the Guarantor may be joined in any action or proceeding
commenced by Guaranteed Party against the Company in respect of any Obligation,
and recovery may be had against the Guarantor in such action or proceeding or in
any independent action or proceeding against the Guarantor, without any
requirement that Guaranteed Party first assert, prosecute or exhaust any remedy
or claim against the Company.
7. REPRESENTATIONS AND WARRANTIES. The Guarantor represents and
warrants to Guaranteed Party as follows:
(a) ORGANIZATION AND GOOD STANDING. The guarantor is a corporation duly
organized, validly existing and in good standing under the laws of the State of
Delaware and each jurisdiction in which it currently conducts its business. The
Guarantor has all requisite corporate power and authority to carry on its
business as it is now conducted and as contemplated by this Guaranty, and to
enter into and perform its obligations hereunder.
(b) DUE AUTHORIZATION; NO CONFLICTS. The execution, delivery and
performance by the Guarantor of the Guaranty has been duly and effectively
authorized by all necessary corporate action of the Guarantor. No other
corporate proceedings are necessary to authorize the execution and delivery by
the Guarantor of this Guaranty; and this Guaranty is the valid and binding
obligation of Guarantor, enforceable in accordance with its items, except as
such enforceability may be limited by applicable bankruptcy, insolvency or
similar laws from time to time in effect that affect creditors' rights generally
or by general principles of equity. Neither the execution and delivery of this
Guaranty nor compliance by the Guarantor with any of the provisions hereof will
(i) violate, or conflict with, or result in a breach of any provisions of, or
constitute a default (or an event which, with notice or lapse of time or both,
would constitute a default) under, or result in the termination of, or
accelerate the performance required by, or result in the creation of any lien
upon any of the properties or assets of the Guarantor under any of the terms,
conditions or provisions of, the Certificate of Incorporation or By-Laws of the
Guarantor in effect on the date of this Guaranty (hereinafter, the "Effective
Date") or any agreement or other instrument or obligation to which the Guarantor
is a party at the Effective Date, or by which the Guarantor or any of its
properties or assets or may be bound or affected as of the Effective Date, or
(ii) violate any order, writ, injunction decree, arbitration award, statute,
rule or regulation applicable at the Effective Date to the Guarantor or any of
its properties or assets.
(c) NO CONSENT REQUIRED. No permit, authorization, consent, approval,
waiver, exception, variance, ruling, order decree, exemption, filing, recording,
registration, notice or declaration (collectively, "GOVERNMENTAL APPROVAL"), is
required or to be made on the Guarantor's behalf with any federal, state,
county, municipal, regional, local, territorial or other governmental
department, regulatory body, commission, board, bureau, agency, taxing authority
or other instrumentality (collectively, "GOVERNMENTAL AUTHORITY") to authorize
the execution and delivery of this Guaranty or the taking of any future action
contemplated hereby, except for those
6-4
Governmental Approvals (i) which have already been obtained or (ii) the failure
of which to obtain would not have an adverse effect on the ability of the
Guarantor to perform and satisfy its obligations hereunder.
(d) NO DEFAULT UNDER OTHER AGREEMENTS. The Guarantor is not in default,
and no condition exists that with notice or lapse of time or both would
constitute a default, under any mortgage, deed of trust, indenture or other
instrument or agreement to which it is a party or by which it or any of its
properties or assets may be bound, that would have a material adverse effect on
the Guarantor's ability to perform under this Guaranty; and the Guarantor is not
in violation of any federal, state, or local rules, ordinances, judgments,
decrees, injunctions, writs, interpretations, licenses and permits or orders of
any court, arbitrator (collectively, "REQUIREMENTS OF LAW"), or Governmental
Authority that could have a material adverse effect on the Guarantor's ability
to perform under this Guaranty.
(e) LITIGATION. There is no litigation, proceeding, arbitration or
government investigation pending or, so far as known to the Guarantor,
threatened with respect to or otherwise relating to the Guarantor which if
adversely determined could, in any one case or in the aggregate, have a material
adverse effect on the ability of the Guarantor to comply with its obligations
under this Guaranty.
(f) COMPLIANCE WITH LAW. (i) The Guarantor has complied in all material
respects with all Requirements of Law relating to this Guaranty, the Guarantor
has received no written notice to the effect that, or otherwise been advised in
writing that, it is not in compliance with any requirement of law or
governmental approval relating to this Guaranty, and the Guarantor has no reason
to believe that any currently existing circumstances are likely to result in
violations by the Guarantor of any such requirement of law which could in any
one case or in the aggregate, have a material adverse effect on the ability of
the Guaranty to perform under this Guaranty; and (ii) to the best of the
knowledge of the Guarantor, there is not now pending any proceeding, hearing or
investigation with respect to the adoption of amendments or modifications to any
existing requirement of law or governmental approval with respect to such
matters which, if adopted, would have a material adverse effect on the ability
of the Guarantor to comply with its obligations under the Guaranty.
8. COVENANTS. The guarantor covenants and agrees that, so long as any
part of the Obligations shall remain unpaid, the Guarantor shall:
(a) PERFORMANCE AND COMPLIANCE WITH OTHER AGREEMENTS. Perform and
comply with each of the material provisions of each material indenture, credit
agreement, contract or other agreement by which the Guarantor is bound,
non-performance or non-compliance with which would have a material adverse
effect on its ability to perform its obligations hereunder, except material
contracts or other agreements being contested in good faith.
6-5
(b) PRESERVATION OF CORPORATE EXISTENCE, ETC. Preserve and maintain its
corporate existence and preserve its material rights, franchises and privileges
to conduct its business substantially as conducted on the date hereof.
(c) COMPLIANCE WITH LAWS, ETC. Comply with all Requirements of Law and
Governmental Approvals, non-compliance with which would have a material adverse
effect on its ability to perform its obligations herein, except laws, rules,
regulations and orders being contested in good faith.
(d) NOTICE OF BREACH. Provide, as soon as possible and in any event
within three (3) business days after the occurrence of any default or breach of
the obligations applicable to the Guarantor hereunder, a statement of the Chief
Financial Officer or Vice-President and Treasurer of the Guarantor setting forth
details of the circumstances leading to such breach or default hereof and the
action which the Guarantor proposes to take with respect thereto.
(e) MERGERS, ETC. Not merge with any person, corporation, partnership,
or other entity unless: (i) the surviving and resulting entity agrees in writing
to be bound hereby to the same extent as the Guarantor, and (ii) immediately
after giving effect thereto, no event of default or breach of this Guaranty
shall have occurred and be continuing.
9. NO WAIVER. No failure on the part of Guaranteed Party to exercise,
and no delay in exercising, any right hereunder shall operate as a waiver
thereof; nor shall any single or partial exercise of any right hereunder
preclude any other or further exercise thereof or the exercise of any other
right.
10. CONTINUING GUARANTY. This Guaranty is a continuing guaranty and
shall (i) remain in full force and effect until the payment in full of all
amounts payable under this Guaranty, (ii) be binding upon the Guarantor, its
successors and assigns, and (iii) inure to the benefit of, and be enforceable
by, Guaranteed Party and its successors, transferees and assigns.
11. WAIVER OF NOTICES. The Guarantor hereby unconditionally and
irrevocably waives all notices to and demands upon the Company or the Guarantor
and all other formalities, the omission of any of which or delay in performance
of which, might, but for the provisions of this paragraph, by rule of law, under
equitable principles or otherwise, constitute grounds for relieving or
discharging the Guarantor in whole or in part from its obligations hereunder.
12. NO CONSEQUENTIAL DAMAGES. Neither Party shall be liable to the
other under this Guaranty or otherwise for any exemplary, consequential,
special, or punitive losses or damages that may be incurred by either Party as a
result of their execution of and performance under this Guaranty.
13. FURTHER ASSURANCES. The Guarantor, at its sole cost and expense,
shall cause to be promptly and duly taken, executed, acknowledged and delivered,
such further documents and
6-6
instruments as Guaranteed Party may from time to time reasonably request in
order to carry-out more effectively the intent and purposes of this Guaranty.
14. SEVERABILITY. If any provision of this Guaranty shall be held or
deemed to be or shall, in fact, be illegal, inoperative or unenforceable, the
same shall not affect any other provision or provisions herein contained or
render the same invalid, inoperative or unenforceable to any extent whatsoever.
15. COUNTERPARTS; EFFECTIVENESS. This guaranty may be executed in any
number of counterparts, each of which shall be deemed to be an original but all
of which together shall constitute one and the same instrument. The effective
date of this Guaranty for all purposes shall be the date specified on page one
(1) above.
16. AMENDMENT; WAIVER; REQUIREMENT OF WRITING. this Guaranty cannot be
amended, changed, modified, released or discharged except by a writing signed by
the party against whom enforcement of the amendment, change, modification or
waiver is sought.
17. ADDRESS FOR NOTICES. Any notice, request, consent, waiver or other
communication required or permitted hereunder shall be effective only if it is
in writing and personally delivered or sent by certified or registered mail,
postage prepaid, or by nationally recognized overnight courier, addressed as set
forth below:
If to Guaranteed Party:
The AES Corporation
0000 Xxxxx 00xx Xxxxxx
Xxxxxxxxx, XX 00000
Attention: General Counsel
Telephone: (000) 000-0000
Facsimile: (000) 000-0000
If to Guarantor:
The Xxxxxxxx Companies, Inc.
Xxx Xxxxxxxx Xxxxxx
Xxxxx, XX 00000
Attention: Treasurer
Telephone: (000) 000-0000
Facsimile: (000) 000-0000
or to such other person or address as the addressee may have specified in a
notice duly given to the sender as provided herein. Such notice or communication
shall be deemed to have been given as of the date received by the recipient
thereof.
6-7
18. GOVERNING LAW. This Guaranty shall be construed in accordance with
and governed by the laws of the State of New York without regard to the conflict
of laws provisions of such laws.
19. SUBMISSION TO JURISDICTION. Each of Guaranteed Party and the
Guarantor hereby irrevocably and unconditionally:
(a) submits for itself and its property in any legal action or
proceeding relating to this Guaranty, or for recognition and enforcement of any
judgment in respect thereof, to the exclusive general jurisdiction of the courts
of the State of New York, the courts of the United States of the Southern
District of New York, and appellate courts with jurisdiction over any appeals
therefrom;
(b) consents and agrees that any such action or proceeding may be
brought in and only in such courts and waives any objection that it may now or
hereafter have to the venue of any such action or proceeding in any such court
or that such action or proceeding was brought in an inconvenient court and
agrees not to plead or claim the same;
(c) agrees that service of process in any such action or proceeding may
be effected by mailing a copy thereof by registered or certified mail (or any
substantially similar form of mail), postage prepaid, to its address set forth
in Section 17 of this Guaranty, or at such other address of which the other
party shall have been notified pursuant thereto; and
(d) agrees that nothing herein shall affect the right to effect service
of process in any other manner permitted by law.
20. ASSIGNMENT. This Guaranty may be assigned by the Guarantor only
with prior written consent of Guaranteed Party, which consent shall not be
unreasonably withheld. Guaranteed Party may assign this Guaranty only as
permitted under the Agreement with respect to assignments by Guaranteed Party of
its rights thereunder. This Guaranty shall be binding upon, and inure to the
benefit of, the parties hereto and their respective successors and permitted
assigns.
[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]
6-8
IN WITNESS WHEREOF, the Guarantor and Guaranteed Party have each caused
this Guaranty to be executed on its behalf by its duly authorized office as of
the date shown above.
THE XXXXXXXX COMPANIES, INC.
as Guarantor
By:
--------------------------------------
Name:
Title:
ACCEPTED AND ACKNOWLEDGED:
THE AES CORPORATION
By:
--------------------------------------
Name:
Title:
6-9
EXHIBIT A
AES Red Oak Project
The Xxxxxxxx Companies, Inc.
Guaranty Cap Reduction Schedule
[*]
6-10
APPENDIX 7
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
LIST OF THIRD PARTY ENGINEERS
[To be provided by AES
after the Execution Date pursuant to the Agreement]
APPENDIX 8
SAMPLE MONTHLY BILLING INVOICE
SELLER: AES Red Oak, L.L.C.
0000 X. 00xx Xx.
Xxxxxxxxx, Xxxxxxxx 00000
BUYER: Xxxxxxxx Energy Marketing & Trading Company
Xxx Xxxxxxxx Xxxxxx
Xxxxx, Xxxxxxxx 00000
BILLING
PERIOD: ____________________________________________________
[*]
APPENDIX 9
FUEL CONVERSION SERVICES, CAPACITY AND
ANCILLARY SERVICES PURCHASE AGREEMENT
OPERATING SPECIFICATIONS
As determined by the engineering, procurement and construction contractor
and as may be revised from time to time pursuant to the Agreement
[to be provided as soon as reasonably practicable after
the Execution Date but in no event later than the Commercial Operation Date]
EXHIBIT 1 Allowable Dispatch Curve
EXHIBIT 2 Heat Rate Target
EXHIBIT 3 Temperature Adjusted Unforced Capacity
EXHIBIT 4 Temperature Adjusted Facility Capacity
EXHIBIT 5 Natural Gas Volumes for Successful Start-ups and
Associated Shutdowns
EXHIBIT 6 Allocated Start-up Duration
EXHIBIT 7 Estimated Reactive Capability Curve
EXHIBIT 8 Estimated Range of Automatic Regulation
Exhibit 10.1
AES RED OAK, L.L.C.
February 21, 2000
Xxxxxx X. Xxxxxx, Vice President
Xxxxxxxx Energy Marketing & Trading Company
Xxx Xxxxxxxx Xxxxxx
Xxxxx, Xxxxxxxx 00000
Re: Amendment No. 1 to the Fuel Conversion Services, Capacity and Ancillary
Services Purchase Agreement
Dear Phil:
AES Red Oak, L.L.C. and Xxxxxxxx Energy Marketing & Trading Company (together,
the "Parties") entered into that certain Fuel Conversion Services, Capacity and
Ancillary Services Purchase Agreement, dated September 17, 1999 (the
"Agreement"). The Parties hereby agree to amend the Agreement, as follows:
1. Section 1.1 shall be revised to include the following
definitions:
[*]
"Major Maintenance Reserve Account" - an account
established pursuant to Seller's financing documents that will
be funded on a monthly basis in amounts necessary to cover
expected costs of major maintenance required at the major
maintenance intervals.
2. Section 10.8(b) shall be revised to read as follows:
[*]
[*]
3. [*]
4. [*]
5. In Section II.B of Appendix 1, "Section 10.9" in the first
paragraph shall be changed to "Section 10.8."
6. [*]
[*]
Except as set forth in the Amendment No. 1, the Agreement remains unchanged and
in full force and effect.
Please note the agreement of Xxxxxxxx Energy Marketing & Trading Company with
this Amendment No. 1 to the Agreement by signing below.
Sincerely,
/s/ Xxxxxxx Xxxxxx
Xxxxxxx Xxxxxx for
AES Red Oak, L.L.C.
Acknowledged and Agreed,
/s/ Xxxxxx X. Xxxxxx
Xxxxxx X. Xxxxxx for
Xxxxxxxx Energy Marketing & Trading Company
