EXHIBIT 10.14(g)
UNITED STATES OF AMERICA
DEPARTMENT OF TRANSPORTATION
MARITIME ADMINISTRATION
COOPERATIVE AGREEMENT
PROJECT NUMBER: DTMA91-95-H-00069
MODIFICATION: 0005
TITLE: "Integrated Shipboard Information Technology Platform (ISIT)
FUNDING DATA: N/A
RECIPIENT NAME Marine Management Systems
AND ADDRESS: 000 Xxxx Xxxxxx
Xxxxxxxx, XX 00000
AGENCY NAME AND DOT/Maritime Administration
ADDRESS: Office of Acquisition, MAR-384
000 Xxxxxxx Xxxxxx, XX, Xxxx 0000
Xxxxxxxxxx, X.X. 00000
MODIFICATION Article 10, Modifications
AUTHORITY:
DESCRIPTION:
1. In accordance with Article 13, Payable Milestones, the attached payable
milestones dated January 14, 1977 are hereby incorporated into the agreement.
2. Article 17 - Period of Performance is changed from "twenty four consecutive
months" to "twenty eight consecutive months," for a four month extension to
November 30, 1977.
3. All other terms and conditions of the Cooperative Agreement remain unchanged.
MARITIME ADMINISTRATION
DEPARTMENT OF TRANSPORTATION
/s/ Xxxx X. Xxxx
--------------------------------
Xxxx X. Xxxx
Agreements/Contracting Officer
Date: Feb 6 1997
---------------------------
January 14, 1997
ISIT Consortium
Attachment #4 (Payable Milestones)
Cooperative Agreement DTMA91-95-H-00069
Modification No. 5
Project Payable Milestones
Adjusted for November 1996 Schedule Change
(Milestone 1-10 Unchanged)
Enclosure (1) to letter
dated January 14, 1997
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 11
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
3.1 System Integration & Test System Integration Test Plan - Draft
-------------------------------------------------------------------------------------------------------------------
4.1 ASTM Standards Development F25 Ballot Complete
-------------------------------------------------------------------------------------------------------------------
7.1 Demonstration Test Plan Demonstration Test Plan - Draft
-------------------------------------------------------------------------------------------------------------------
7.2 Demonstration Design Demonstration Design - Draft
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 11: $99,097
TARGET COMPLETION DATE: FEBRUARY 14, 1997
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 12
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
3.1 System Integration and Test Land Based Test Plan - Final
-------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review No. 6 - Test Readiness
(includes Software Progress Audit/
Demonstration #1)
-------------------------------------------------------------------------------------------------------------------
7.1 Demonstration Test Plan Demonstration Test Plan - Final
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 12: $97,219
TARGET COMPLETION DATE: APRIL 5, 1997
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 13
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
4.2 ABS Guidelines Development Pre-Release Draft
-------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Technical Progress Report No. 6 (includes
Software Progress Audit/Demonstration #2)
-------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board Advisory Board Meeting No. 5
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 13: $57,480
TARGET COMPLETION DATE: MAY 8, 1997
1 of 3
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 14
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
3.1 System Integration & Test System Integration and Test Report - Preliminary
-------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Data Acquisition
-------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Executive
-------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Communication Services
-------------------------------------------------------------------------------------------------------------------
7.2 Demonstration Design Demonstration Design - Final
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 14: $64,529
TARGET COMPLETION DATE: JULY 11, 1997
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 15
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
3.1 System Integration and Test System Integration Test Report - Final
-------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Land Based Test Report - Final
-------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review No. 7; Final Presentation;
Phase I (includes Software Progress Audit/
Demonstration #3 and #4)
-------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Progress Report No. 7
-------------------------------------------------------------------------------------------------------------------
7.3 Demonstration Install/Checkout Shipboard Installation/Checkout Complete
-------------------------------------------------------------------------------------------------------------------
7.4 Demonstration Install/Checkout Shore side Installation/Checkout Complete
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 15: $23,747
TARGET COMPLETION DATE: AUGUST 27, 1997
2 of 3
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 16
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board Advisory Board Meeting No. 6
-------------------------------------------------------------------------------------------------------------------
7.5 Demonstration Test Demonstration Test Preliminary Report
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 16: $11,690
TARGET COMPLETION DATE: OCTOBER 1, 1997
-------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 17
-------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
-------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Final Project Report
-------------------------------------------------------------------------------------------------------------------
7.5 Demonstration Test Demonstration Assessment Report
-------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 17: $10,368
TARGET COMPLETION DATE: NOVEMBER 25, 1997
3 of 3
