1
LEASE AGREEMENT
BY AND BETWEEN
SOUTH BAY/SAN XXXXX ASSOCIATES
AND
AUSPEX SYSTEMS, INC.
DATED AS OF JANUARY , 1997
2
TABLE OF CONTENTS
Page
----
1. Parties................................................................. 1
2. Demise of Premises...................................................... 1
3. Lease Term.............................................................. 1
A. Lease Term..................................................... 1
B. Commencement Date.............................................. 1
C. Commencement Date Memorandum................................... 2
X. Xxxxx in Completion of Buildings............................... 2
E. Options to Extend.............................................. 2
F. Early Entry.................................................... 3
4. Rent.................................................................... 3
A. Time of Payment................................................ 3
B. Monthly Installment............................................ 4
C. Tenant Improvement Allowance................................... 6
D. Late Charge.................................................... 6
E. Additional Rent................................................ 7
F. Place of Payment............................................... 7
G. Advance Payment................................................ 7
5. Security Deposit........................................................ 7
6. Use of Premises......................................................... 8
A. Restrictions on Use............................................ 8
B. Initial Occupancy.............................................. 8
7. Taxes and Assessments................................................... 8
A. Tenant's Property.............................................. 8
B. Property Taxes................................................. 8
C. Property Taxes Defined......................................... 9
D. Other Taxes.................................................... 9
E. Tenant's Right to Contest...................................... 9
8. Insurance............................................................... 10
A. Indemnity...................................................... 10
B. Liability Insurance............................................ 10
C. Property Insurance............................................. 11
D. Tenant's Property Insurance.................................... 11
E. Mutual Waiver of Subrogation................................... 11
i
3
Page
----
9. Utilities............................................................... 12
10. Repairs and Maintenance................................................. 12
A. Landlord's Repairs............................................. 12
B. Tenant's Repairs............................................... 13
11. Alterations............................................................. 15
A. Limitations.................................................... 15
B. Tenant's Rights................................................ 15
C. Alterations Required by Law.................................... 16
12. Acceptance of the Premises.............................................. 16
13. Default................................................................. 16
A. Events of Default.............................................. 16
B. Remedies....................................................... 17
C. Waivers........................................................ 19
14. Destruction............................................................. 19
A. Landlord's Duty to Restore..................................... 19
B. Landlord's Right to Terminate.................................. 20
C. Tenant's Right to Terminate.................................... 21
D. Abatement of Rent.............................................. 21
15. Condemnation............................................................ 22
A. Definition of Terms............................................ 22
B. Rights......................................................... 22
C. Total Taking................................................... 22
D. Partial Taking................................................. 22
16. Mechanics' Lien......................................................... 23
17. Inspection of the Premises.............................................. 23
18. Compliance with Laws.................................................... 23
19. Subordination........................................................... 23
A. Priority....................................................... 24
B. Subsequent Security Instruments................................ 24
C. Documents...................................................... 24
D. Tenant's Attornment............................................ 24
20. Holding Over............................................................ 24
ii
4
Page
----
21. Notices................................................................. 25
22. Attorneys' Fees......................................................... 25
23. Subleasing and Assignment............................................... 26
A. Landlord's Consent Required.................................... 26
B. Transferee Information Required................................ 26
C. Landlord's Rights.............................................. 26
D. Permitted Transfers............................................ 27
24. Successors.............................................................. 28
25. Mortgagee Protection.................................................... 28
26. Estoppel Certificate.................................................... 28
27. Surrender of Lease Not Merger........................................... 29
28. Waiver.................................................................. 29
29. General................................................................. 29
A. Captions....................................................... 29
B. Definition of Landlord......................................... 29
C. Time of Essence................................................ 29
D. Severability................................................... 29
E. Quiet Enjoyment................................................ 30
F. Law............................................................ 30
G. Agent.......................................................... 30
H. Lender......................................................... 30
I. Force Majeure.................................................. 30
30. Sign.................................................................... 30
31. Interest on Past Due Obligations........................................ 31
32. Surrender of the Premises............................................... 31
33. Authority............................................................... 31
34. CC&Rs................................................................... 31
35. Brokers................................................................. 32
iii
5
Page
----
36. Limitation on Landlord's Liability...................................... 32
37. Hazardous Material...................................................... 33
A. Definitions.................................................... 33
B. Landlord's Obligation.......................................... 33
C. Permitted Use.................................................. 33
D. Hazardous Materials Management Plan............................ 34
E. Use Restriction................................................ 35
F. Tenant Indemnity............................................... 35
G. Compliance..................................................... 35
H. Assignment and Subletting...................................... 36
I. Surrender...................................................... 36
J. Right to Appoint Consultant.................................... 36
K. Holding Over................................................... 37
L. Existing Environmental Reports................................. 37
M. Provisions Survive Termination................................. 37
N. Controlling Provisions......................................... 37
38. Landlord's Default...................................................... 37
39. Condition to Effectiveness.............................................. 38
iv
6
LIST OF EXHIBITS
Exhibit "A" - Legal Description of Parcel...........................................39
Exhibit "B" - Site Plan.............................................................40
Exhibit "C" - Improvement Agreement.................................................41
Exhibit "D" - Commencement Date Memorandum..........................................57
Exhibit "E" - List of Hazardous Materials Tenant Will Use on The Premises...........58
Exhibit "F" - Description of Existing Environmental Reports.........................59
Exhibit "G" - Preliminary Title Report..............................................63
Exhibit "H" - CCR's and Excluded Obligations........................................64
v
7
LEASE AGREEMENT
1. Parties. This Lease, dated for reference purposes as of January ,
1997, is made by and between South Bay/San Xxxxx Associates, a California
general partnership ("LANDLORD"), and Auspex Systems, Inc., a Delaware
corporation ("TENANT").
2. Demise of Premises. Landlord hereby leases to Tenant and Tenant
hereby leases from Landlord, upon the terms and conditions hereinafter set
forth, those certain premises (the "PREMISES") situated in the City of Santa
Xxxxx, County of Santa Xxxxx, State of California, described as follows:
A. That Parcel of real property more particularly described in
Exhibit "A" attached hereto (the "PARCEL");
B. Three (3) buildings two (2) stories high to be constructed
by Landlord and located on the Parcel as shown on the site plan attached hereto
as Exhibit "B" containing approximately one hundred seventy one thousand three
hundred eighty two (171,382) square feet (collectively, the "BUILDINGS" and
individually, "BUILDING").
C. The shells and the associated site improvements for all
Buildings (the "BUILDING SHELLS") to be constructed by Landlord in accordance
with the provisions of the Improvement Agreement attached hereto as Exhibit "C"
(the "IMPROVEMENT AGREEMENT").
D. The improvements (the "TENANT IMPROVEMENTS") to be
constructed by Landlord in and about the Buildings in accordance with the
provisions of the Improvement Agreement. The Building Shells and the Tenant
Improvements are collectively referred to in this Lease as the "IMPROVEMENTS".
3. Lease Term
A. Lease Term. The term of this Lease (the "INITIAL LEASE
TERM") shall be for twelve (12) years commencing on the Commencement Date (as
defined below) and ending twelve (12) years thereafter unless sooner terminated
pursuant to any provision hereof.
B. Commencement Date. As used in this Lease, the term
"COMMENCEMENT DATE" shall mean the later of March 1, 1998, or the date when all
of the following have occurred with respect to the Improvements:
(i) The construction of all of the Improvements has
been substantially completed in accordance with the provisions of the
Improvement Agreement attached hereto and the Final Plans therefor (except for
minor punchlist items which do not substantially interfere with Tenant's use of
the Premises), and all utilities are connected and available for Tenant's use;
(ii) A certificate of occupancy or its equivalent
(including a final
1
8
building inspection) with respect to the Improvements has been issued by the
City of Santa Xxxxx; and
(iii) Landlord has given Tenant written notice that
the events described in (i) and (ii) above have occurred.
C. Commencement Date Memorandum. Within thirty (30) days
following the Commencement Date, Tenant shall execute and deliver to Landlord a
Commencement Date Memorandum in the form attached hereto as Exhibit "D"
acknowledging the actual Commencement Date, the Expiration Date and the initial
Monthly Installment (as defined in Subparagraph 4.A. hereof) of rent.
X. Xxxxx in Completion of Buildings. Notwithstanding the
Commencement Date set forth in Subparagraph 3.B. above, if the construction of
the Improvements to the Buildings have not been substantially completed in
accordance with the provisions of the Improvement Agreement attached hereto and
the Final Plans therefor (except for minor punchlist items which do not
substantially interfere with Tenant's use of the Premises) by the later of (i)
January 31, 1998, or (ii) eleven (11) months following the issuance of all
required building permits for the construction of the Improvements to the
Building (provided such time periods in (i) and (ii) shall be extended by force
majeure delays and Tenant Delays as defined in Exhibit "C" hereto) (the
"BUILDING COMPLETION DATE"), Tenant shall have the option to terminate this
Lease (which shall be Tenant's sole remedy for such an event), which option may
be exercised only by delivery to Landlord of a written notice of election to
terminate within fifteen (15) days after the Building Completion Date and prior
to substantial completion of the Improvements to the Buildings.
E. Options to Extend
(i) Tenant shall have three (3) successive options
(the "OPTIONS") to extend the Initial Lease Term for successive terms of sixty
(60) months each (collectively, the "EXTENDED TERMS" and individually, the
"FIRST EXTENDED TERM", the "SECOND EXTENDED TERM" and the "THIRD EXTENDED
TERM"). The Initial Term as may be extended by Tenant shall be referred to
herein as the "LEASE TERM."
(ii) Tenant shall exercise each Option, if at all, by
giving Landlord notice of Tenant's intention to do so at least two hundred
seventy (270) days prior to the expiration of the then existing Lease Term. In
no event shall any purported exercise of the Option by Tenant be effective if
(a) an Event of Default (as defined in Subparagraph 13.A. hereof) exists at the
time of such exercise or at the time such Extended Term would otherwise have
commenced, or (b) Tenant had not timely exercised each previous Option(s) to
extend the Lease. The Extended Terms shall be upon all of the terms and
conditions hereof, except that the Monthly Installment and method of rental
adjustment for each Extended Term shall be determined as set forth in
Subparagraph 4.B.(iii) hereof. Unless expressly mentioned and approved in the
written consent of Landlord referred to in Paragraph 23 hereof, the option
rights
2
9
of Tenant under this paragraph are granted for Tenant's personal benefit and may
not be assigned or transferred by Tenant.
F. Early Entry. Tenant may enter the Premises
prior to the Commencement Date to install fixtures and equipment therein,
provided Tenant first obtains the prior written approval of Landlord for such
entry, which approval shall not be unreasonably withheld but which Landlord may
withhold if Landlord determines in its reasonable discretion that such entry
will delay completion of construction of the Improvements which Landlord is
required to construct pursuant to Exhibit "C". If Landlord permits Tenant to so
enter upon the Premises, such entry shall be subject to all of the terms and
conditions of this Lease, excepting only the obligation to pay the Monthly
Installment of rent or Additional Rent (as defined in Subparagraph 4.E. below),
and the duty to pay utility consumption costs and insurance. Tenant shall
coordinate its entry onto the Premises with Landlord and the contractors and
other personnel employed by Landlord. At all times during Tenant's right of
entry, Landlord and Tenant shall reasonably cooperate to refrain from
interfering with the construction activities of the other party's personnel;
provided, Landlord shall not be required to cooperate with Tenant if such
cooperation results in a delay in completing the Improvements. In any case,
Tenant shall repair any damage to the Improvements constructed by Landlord
resulting from the entry upon the Premises by Tenant or Tenant's Agents (as that
term is defined in Subparagraph 29.G.) prior to the Commencement Date or caused
by the installation of fixtures and equipment by Tenant or Tenant's Agents. If
the entry by Tenant or Tenant's Agents upon the Premises prior to the
Commencement Date interferes with Landlord's construction activities, then
Landlord shall give Tenant written notice requesting that Tenant cease such
interference. If Tenant does not immediately comply with such notice from
Landlord requesting that Tenant cease interference with Landlord's construction
activities, and if such failure to comply causes a delay in completing the
construction of the Improvements, then the Commencement Date shall be deemed to
have occurred on the date the Improvements would have been completed had there
been no such delay caused by Tenant or its Agents.
4. Rent.
A. Time of PaymentA. Time of Payment. Tenant shall pay to
Landlord as rent for the Premises the respective sums specified in Subparagraph
4.B. below (the "MONTHLY INSTALLMENT") each month in advance on the first day of
each calendar month, without deduction or offset, prior notice or demand,
commencing on the Commencement Date and continuing through the Lease Term,
together with such additional rents as are payable by Tenant to Landlord under
the terms of this Lease. The Monthly Installment for any period during the Lease
Term which is less than one (1) full month shall be a pro rata portion of the
Monthly Installment based upon a thirty (30) day month.
B. Monthly Installment
(i) The Monthly Installment of rent for the first
thirty (30) months following the Commencement Date shall be Two Hundred Sixty
Five Thousand Six Hundred
3
10
Forty Two and 10/100 Dollars ($265,642.10).
(ii) Rental Adjustment. The Monthly Installment shall
be adjusted at the beginning of the thirty-first (31st) month following the
Commencement Date and every thirty (30) months thereafter during the Initial
Lease Term (the "RENTAL ADJUSTMENT DATES"), to reflect any increase in the cost
of living. The adjustment or adjustments, if any, shall be calculated upon the
basis of the United States Department of Labor, Bureau of Labor Statistics
Consumer Price Index for All-Urban Consumers, for San Francisco-Oakland-San Xxxx
(1982 - 1984 = 100), hereafter referred to as the "INDEX." The last published
Index in effect on the Commencement Date shall be considered the "BASE". On each
Rental Adjustment Date, the Monthly Installment then in effect shall be
increased to an amount equal to the Monthly Installment in effect as of the
first full month of the Lease Term multiplied by a fraction, the numerator of
which is the Index as of such Rental Adjustment Date, and the denominator of
which is the "Base"; provided, the Monthly Installment shall not increase by
less than three percent (3%) per annum compounded annually or greater than seven
percent (7%) per annum compounded annually on each Rental Adjustment Date. When
the adjusted Monthly Installment is determined upon each Rental Adjustment Date,
Landlord shall give Tenant written notice to that effect indicating how the new
Monthly Installment figure was computed in accordance with this Subparagraph
4.B.(ii). If the Index does not exist on any Rental Adjustment Date in the same
format as referred to in this paragraph, Landlord shall substitute (using
conversion factors, as appropriate) in lieu thereof the index most nearly
comparable to the Index then published by the Bureau of Labor Statistics, or
successor or similar governmental agency, or if no governmental agency then
publishes an index, Landlord shall substitute therefor the most nearly
comparable index then published by a reputable private organization.
(iii) Extended Term Rent.
(a) As of the commencement of each Extended
Term, the Monthly Installment and the method of rental adjustment (including the
timing of adjustments and the basis for calculating the adjustments) for each
Extended Term shall be the fair market rental, as of the commencement date of
the Extended Term, for the Premises, as improved, and a method and timing of
rental adjustments consistent with rental adjustment practices then prevailing
in the marketplace for comparably sized projects designed for similar uses
within a three (3) mile radius of the Premises. In the event the parties fail to
agree upon the amount of the Monthly Installment and the method of rental
adjustment for any of the Extended Terms within thirty (30) days after
Landlord's receipt of Tenant's notice exercising the Option for such Extended
Term, the Monthly Installment and the method of rental adjustment for such
Extended Term shall be determined by appraisal in the manner hereafter set
forth.
(b) In the event it becomes necessary under
this Subparagraph 4.B.(iii)(b) to determine the fair market rent to be used as
the Monthly Installment and the method and timing of rental adjustments of the
Premises by appraisal, Landlord and Tenant each shall appoint a real estate
appraiser who shall be a member of The Appraisal Institute ("TAI") and who shall
have a minimum of five (5) years of commercial appraisal experience in Santa
4
11
Xxxxx County and such appraisers shall each determine the fair market rent for
the Premises, and the method and timing of rental adjustments taking into
account the value of the Premises (excluding Tenant's Property (as defined
below) which Tenant shall be allowed to remove upon the expiration of this
Lease), the amenities provided and prevailing comparable rentals and rental
adjustment practices then prevailing in the marketplace for comparably sized
projects designed for similar uses within a three (3) mile radius of the
Premises. Such appraisers shall, within twenty (20) business days after their
appointment, complete their appraisals and submit their appraisal reports to
Landlord and Tenant. If the fair market rent of the Premises established in the
two (2) appraisals varies by five percent (5%) or less of the higher rental, the
average of the two shall be controlling. If said fair market rent varies by more
than five percent (5%) of the higher rental, said appraisers, within ten (10)
days after submission of the last appraisal, shall appoint a third appraiser who
shall be a member of TAI and who shall have a minimum of five (5) years of
commercial appraisal experience in Santa Xxxxx County. Such third appraiser
shall, within twenty (20) business days after his appointment, determine by
appraisal the fair market rent of the Premises, taking into account the same
factors referred to above, and submit his appraisal report to Landlord and
Tenant. The fair market rent determined by the third appraiser for the Premises
shall be averaged with the fair market rent determined by the one of the initial
two appraisers that is closest to that of the third appraiser, unless the third
appraiser's determination of the rent is less than that set forth in the lower
appraisal previously obtained, in which case the value set forth in said lower
appraisal shall be controlling, or unless it is greater than that set forth in
the higher appraisal previously obtained, in which case the rental set forth in
said higher appraisal shall be controlling. The method of adjusting rental
periodically, including the manner and timing of such adjustments, shall be as
determined by the initial two appraisers, if they agree on a single method;
otherwise, it shall be as determined by the third appraiser. If either Landlord
or Tenant fails to appoint an appraiser, or if an appraiser appointed by either
of them fails, after his appointment, to submit his appraisal within the
required period in accordance with the foregoing, the appraisal submitted by the
appraiser properly appointed and timely submitting his appraisal shall be
controlling. If the two appraisers appointed by Landlord and Tenant are unable
to agree upon a third appraiser within the required period in accordance with
the foregoing, application shall be made within twenty (20) days thereafter by
either Landlord or Tenant to TAI, which shall appoint a member of said institute
willing to serve as appraiser. Each party shall bear the cost of their own
appraiser and the cost of the third appraiser under this Subparagraph shall be
borne equally by Landlord and Tenant.
C. Tenant Improvement Allowance
(i) Landlord shall make available for the payment of
all TI Costs (as defined in the Improvement Agreement) an amount equal to Four
Million Two Hundred Eighty Four Thousand Five Hundred Fifty Dollars ($4,284,550)
(the "TI ALLOWANCE"). To the extent that TI Costs exceed the total TI Allowance,
Tenant shall pay the amount of such excess (with such excess referred to herein
as "TENANT'S TI CONTRIBUTION"). After Landlord has expended the total TI
Allowance, Tenant's TI Contribution shall be paid by Tenant to Landlord in
installments as and when needed by Landlord to pay TI Costs that have been
incurred by Landlord for the Buildings, with each installment to be paid within
five (5) days after Landlord
5
12
notifies Tenant that a progress payment toward TI Costs is to be made and
supplies to Tenant an appropriate accounting of all TI Costs incurred by
Landlord and such other documentation as a construction lender might reasonably
request. Such progress payments shall not be requested any more frequently than
every thirty (30) days.
(ii) Prior to the commencement of construction of the
Tenant Improvements, Tenant shall, if requested to do so by Landlord, provide
reasonable assurances to Landlord's Lender (as that term is defined in
Subparagraph 29.H.) that the funds necessary to pay Tenant's TI Contribution
will be immediately available to Landlord as and when needed to pay all TI Costs
after Landlord has expended the TI Allowance, which assurances shall be
reasonably satisfactory to Landlord and Landlord's Lender.
D. Late Charge. Tenant acknowledges that late payment by
Tenant to Landlord of rent and other sums due hereunder will cause Landlord to
incur costs not contemplated by this Lease, the exact amount of which will be
extremely difficult to ascertain. Such costs include, but are not limited to,
processing and accounting charges, and late charges which may be imposed on
Landlord by the terms of any mortgage or deed of trust covering the Premises.
Accordingly, if any Monthly Installment, Additional Rent or any other sum due
from Tenant shall not be received by Landlord within ten (10) days after
Landlord's delivery to Tenant of written notice stating that such amount has not
been paid when due, then Tenant shall pay to Landlord, as additional rent, a
late charge equal to six percent (6%) of such overdue amount. The parties hereby
agree that such late charge represents a fair and reasonable estimate of the
costs Landlord will incur by reason of late payment by Tenant. Acceptance of
such late charge by Landlord without payment of the overdue amount shall in no
event constitute a waiver of Tenant's default with respect to such overdue
amount, nor prevent Landlord from exercising any of its other rights and
remedies granted hereunder.
E. Additional RentE. Additional Rent. All taxes, insurance
premiums, late charges, costs, expenses and other sums which Tenant is required
to pay under this Lease, together with all interest and penalties that may
accrue thereon in the event of Tenant's failure to pay such amounts, and all
reasonable damages, costs, and attorneys' fees and expenses which Landlord may
incur by reason of any default of Tenant or failure on Tenant's part to comply
with the terms of this Lease, shall be deemed to be additional rent ("ADDITIONAL
RENT") and shall be paid in addition to the Monthly Installment of rent, and, in
the event of nonpayment by Tenant, Landlord shall have all of the rights and
remedies with respect thereto as Landlord has for the nonpayment of the Monthly
Installment of rent. All items of Additional Rent, but excluding such taxes and
assessment, utilities and insurance costs which are to be paid directly by
Tenant or reimbursed by Tenant to Landlord, shall include an additional two
percent (2%) of the actual expenditure or amount due in order to compensate
Landlord for accounting, management and processing services.
F. Place of Payment. Rent shall be payable in lawful money of
the United States of America to Landlord at 000 Xxxxxxxx Xxxxxx, Xxxxxxxx,
Xxxxxxxxxx 00000 or to such other person(s) or at such other place(s) as
Landlord may designate in writing.
6
13
G. Advance Payment. Concurrently with the execution of this
Lease, Tenant shall pay to Landlord the sum of Two Hundred Sixty Five Thousand
Six Hundred Forty Two and 10/100 Dollars ($265,642.10) to be applied to the
Monthly Installment of rent first accruing under this Lease.
5. Security Deposit. Concurrently with the execution of this Lease,
Tenant shall pay to Landlord the sum of Two Hundred Sixty Five Thousand Six
Hundred Forty Two and 10/100 Dollars ($265,642.10) (the "SECURITY DEPOSIT") to
secure the faithful performance by Tenant of each term, covenant and condition
of this Lease. If Tenant shall at any time fail to make any payment or fail to
keep or perform any term, covenant or condition on its part to be made or
performed or kept under this Lease, Landlord may, but shall not be obligated to
and without waiving or releasing Tenant from any obligation under this Lease,
use, apply or retain the whole or any part of the Security Deposit (A) to the
extent of any sum due to Landlord; (B) to make any required payment on Tenant's
behalf; or (C) to compensate Landlord for any loss, damages, attorneys' fees or
expense sustained by Landlord due to Tenant's default. In such event, Tenant
shall, within five (5) days of written demand by Landlord, remit to Landlord
sufficient funds to restore the Security Deposit to its original sum. No
interest shall accrue on the Security Deposit. Landlord shall not be required to
keep the Security Deposit separate from its general funds. The Security Deposit,
less any sums owing to Landlord or which Landlord is otherwise entitled to
retain, shall be returned to Tenant within thirty (30) days after the
termination of this Lease and vacancy of the Premises by Tenant.
6. Use of Premises.
A. Restrictions on Use. Tenant shall use the Premises only in
conformance with applicable governmental laws, for general office, engineering,
research and development, light assembly, testing, warehousing and related
lawful uses, and for no other purpose without the consent of Landlord. Tenant
shall indemnify, defend and hold Landlord harmless against any loss, expense,
damage, attorneys' fees or liabilities to the extent the foregoing arises out of
the failure of Tenant to comply with any Law (as defined in Subparagraph 29.F.)
applicable to Tenant's use and occupancy of the Premises. Tenant shall not
commit or suffer to be committed, any waste upon the Premises, or any nuisance,
or other acts or things which may disturb the quiet enjoyment of any other
occupant of buildings adjacent to the Premises, or allow any sale by auction
upon the Premises, or allow the Premises to be used for any unlawful purpose, or
place any loads upon the floor, walls or ceiling which would endanger the
structure, or place any harmful liquids in the drainage system of the Premises.
No waste materials or refuse shall be dumped upon or permitted to remain upon
any part of the Premises outside of the Buildings, except in trash containers
placed inside exterior enclosures designated for that purpose by Landlord and
except in compliance with all applicable Law. No materials, supplies, equipment,
finished products or semifinished products, raw materials or articles of any
nature shall be stored upon or permitted to remain on any portion of the Parcel
outside of the Buildings. Tenant shall strictly comply with the provisions of
Paragraph 37 below.
7
14
B. Initial Occupancy. Tenant shall be obligated to take
possession and enter into occupancy of two (2) of the three (3) Buildings of the
Premises within thirty (30) days following the Commencement Date.
7. Taxes and Assessments
A. Tenant's Property. Tenant shall pay before delinquency any
and all taxes and assessments, license fees and public charges levied, assessed
or imposed upon or against Tenant's fixtures, equipment, furnishings, furniture,
appliances and personal property installed or located on or within the Premises
("Tenant's Property"). Tenant shall use its best efforts to cause all Tenant's
Property to be assessed and billed separately from the real property of
Landlord. If any of Tenant's Property shall be assessed with the Premises,
Tenant shall pay Landlord the taxes attributable to Tenant within ten (10) days
after receipt of a written statement from Landlord setting forth the taxes
applicable to Tenant's Property.
B. Property Taxes. Tenant shall pay, as Additional Rent, one
hundred percent (100%) of all property taxes (as defined in Subparagraph 7.C.
below) levied or assessed with respect to the Premises which are attributable to
the Lease Term. Tenant shall pay such Property Taxes to Landlord not later than
(i) ten (10) days prior to the delinquency date of such Property Taxes, or (ii)
twenty (20) days after receipt of billing, whichever is later. If Tenant fails
to do so, Tenant shall reimburse Landlord, on demand, for all interest, late
fees and penalties that the taxing authority charges Landlord. In the event
Landlord's Lender requires an impound for Property Taxes, then on the first day
of each month during the Lease Term, Tenant shall pay Landlord one twelfth
(1/12) of the annual Property Taxes. Tenant's liability hereunder shall be
prorated to reflect the commencement and termination dates of this Lease.
C. Property Taxes Defined. For the purpose of this Lease,
"PROPERTY TAXES" means and includes all taxes, assessments (including, but not
limited to, assessments for public improvements or benefits), taxes based on
vehicles utilizing parking areas, taxes based or measured by the rent paid,
payable or received under this Lease, taxes on the value, use, or occupancy of
the Premises, the Buildings and/or the Parcel, and all other governmental
impositions and charges of every kind and nature whatsoever, whether or not
customary or within the contemplation of the parties hereto and regardless of
whether the same shall be extraordinary or ordinary, general or special,
unforeseen or foreseen, or similar or dissimilar to any of the foregoing which,
at any time during the Lease Term, shall be applicable to the Premises, the
Buildings and/or the Parcel or assessed, levied or imposed upon the Premises,
the Buildings and/or the Parcel, or become due and payable and a lien or charge
upon the Premises, the Buildings and/or the Parcel, or any part thereof, under
or by virtue of any present or future laws, statutes, ordinances, regulations or
other requirements of any govern mental authority whatsoever. The term "Property
Taxes" shall not include any federal, state or local net income, documentary
transfer (unrelated to any transfer made of Tenant's interest under this Lease),
franchise (unrelated to Tenant's operations), estate, gift or inheritance tax
imposed on Landlord (the "PROPERTY TAX EXCLUSIONS").
8
15
D. Other Taxes. Tenant shall, as Additional Rent, pay or
reimburse Landlord for any tax based upon, allocable to, or measured by the area
of the Premises or the Buildings or the Parcel; or by the rent paid, payable or
received under this Lease; any tax upon or with respect to the possession,
leasing, operation, management, maintenance, alteration, repair, use or
occupancy of the Premises or any portion thereof; any privilege tax, excise tax,
business and occupation tax, gross receipts tax, sales and/or use tax, water
tax, sewer tax, employee tax, occupational license tax imposed upon Landlord or
Tenant with respect to the Premises; any tax upon this transaction or any
document to which Tenant is a party creating or transferring any of Tenant's
interest or estate in the Premises; provided, however that nothing in this
Subparagraph shall require Tenant to pay any Property Tax Exclusions.
E. Tenant's Right to Contest. Tenant shall have the right, by
appropriate proceedings, to protest or contest any assessment, reassessment or
allocation of Property Taxes or any change therein. In the contest or
proceedings, Tenant may act in its own name and/or the name of Landlord and
Landlord will, at Tenant's request and expense, cooperate with Tenant in any way
Tenant may reasonably require in connection with such contest. Tenant must pay
all Property Taxes as and when required by Subparagraph 7.B., even those which
are the subject of such protest or contest, but Tenant may xxx to recover
overpayments or Property Taxes as part of any such contest. With respect to any
contest of Property Taxes, Tenant shall indemnify and hold Landlord and the
Premises harmless from any liens or damage arising out of such protest or
contest and shall pay any judgment that may be rendered for which Tenant would
otherwise be liable under this Lease without such contest or protest. Any
contest conducted by Tenant under this paragraph shall be at Tenant's expense
and if interest or late charges become payable as a result of such contest or
protest, Tenant shall pay the same. Any tax assessments reimbursed to Landlord
as a consequence of such contest shall be reimbursed to Tenant, to the extent
originally paid by Tenant under the terms of this Lease.
8. Insurance.
A. Indemnity. Tenant agrees to indemnify, protect and defend
Landlord against and hold Landlord harmless from any and all claims, causes of
action, judgments, obligations or liabilities, and all reasonable expenses
incurred in investigating or resisting the same (including reasonable attorneys'
fees), to the extent they arise out of, the opera tion, maintenance, use or
occupancy of the Premises by Tenant and/or its Agents (except to the extent they
arise from the negligence or willful misconduct of Landlord or its Agents). This
Lease is made on the express understanding that Landlord shall not be liable
for, or suffer loss by reason of, injury to person or property, from whatever
cause (except to the extent it arises from the negligence or willful misconduct
of Landlord or its Agents), which in any way may be connected with the
operation, maintenance, use or occupancy of the Premises by Tenant and/or its
Agents specifically including, without limitation, any liability for injury to
the person or property of Tenant or its Agents.
B. Liability Insurance. Tenant shall, at Tenant's expense,
obtain and keep in force during the term of this Lease a policy of commercial
general liability insurance insuring
9
16
Landlord and Tenant against claims and liabilities arising out of the operation,
maintenance, use, or occupancy of the Premises. Such insurance shall provide
combined single limit coverage of not less than Five Million Dollars
($5,000,000.00) per occurrence. Landlord shall have the right to require Tenant
to increase the amount of coverage of such public liability insurance to the
extent reasonably necessary to bring such insurance coverage into conformity
with the level of coverage commonly carried by similar businesses in California
leasing comparable buildings in the vicinity of the Premises, which right
Landlord may exercise no more frequently than once every two (2) years during
the Lease Term. The insurance shall be provided by companies (i) admitted to
issue insurance in California and (ii) having a general policyholders' rating of
at least "A" and a financial rating of at least "VIII" as set forth in the most
current issue of Best's Insurance Guide. Tenant shall deliver to Landlord, prior
to possession, and at least thirty (30) days prior to the expiration of any
insurance policy required hereby, a certificate of insurance evidencing the
existence of such policy and the certificate shall certify that the policy (1)
names Landlord as an additional insured, (2) shall not be canceled or altered
without thirty (30) days prior written notice to Landlord, (3) insures
performance of the indemnity set forth in Subparagraph 8.A. above, (4) the
coverage is primary and any coverage by Landlord is in excess thereto and (5)
contains a cross-liability endorsement.
Landlord may maintain a policy or policies of commercial general
liability insurance insuring Landlord (and such others as are designated by
Landlord), against liability for personal injury, bodily injury, death and
damage to property occurring or resulting from an occurrence in, on or about the
Premises, with such limits of coverage as Landlord may from time to time
determine are reasonably necessary for its protection. Tenant shall, as
Additional Rent, reimburse Landlord for the cost of any such insurance policy
within ten (10) days after receipt of billing.
C. Property Insurance. Landlord shall, at Tenant's expense,
obtain and keep in force during the Lease Term a policy of insurance covering
loss or damage to the Improvements, in the amount of the full replacement value
thereof with an Agreed Amount Endorsement, providing protection against those
perils included within the classification of "special form" insurance, plus a
policy of rental income insurance in the amount of one hundred percent (100%) of
twelve (12) months' rent (including, without limitation, sums payable as
Additional Rent), together with such additional coverages (such as earthquake
and/or flood insurance) which Landlord may elect to maintain from time to time
or which may be required from time to time by Landlord's Lender or by Tenant.
Tenant shall have no interest in nor any right to the proceeds of any insurance
procured by Landlord on the Buildings and Tenant Improvements. Tenant shall pay
to Landlord, as Additional Rent, the cost of such insurance procured and
maintained by Landlord on an annual basis within ten (10) days after receipt of
demand therefore from Landlord. Tenant's liability for the cost of such
insurance shall be prorated as of the commencement and termination of the Lease
Term. Tenant acknowledges that such insurance procured by Landlord shall contain
a deductible which reduces Tenant's cost for such insurance and, in the event of
loss or damage, Tenant shall be required to pay to Landlord the amount of such
deductible; provided, Tenant's liability for such deductible shall not exceed
Twenty Five Thousand Dollars ($25,000), except Tenant's liability for the
deductible on
10
17
Landlord's earthquake insurance shall not exceed ten percent (10%) of the policy
amount.
D. Tenant's Property Insurance. Tenant acknowledges that the
insurance to be maintained Landlord on the Premises pursuant to Paragraph 8.C.
above will not insure any of Tenant's Property. Accordingly, Tenant, at Tenant's
own expense, shall maintain in full force and effect on all of Tenant's Property
in the Premises, a policy of "special form" coverage insurance to the extent of
at least ninety percent (90%) of insurable value of such property.
E. Mutual Waiver of Subrogation. Notwithstanding anything to
the contrary contained in this Lease, Tenant and Landlord hereby mutually waive
their respective rights of recovery against each other of any loss of or damage
to the property of either party, to the extent such loss or damage is insured by
either party at the time of such loss or damage or required to be insured
pursuant to this Lease by the party having the right of recovery against the
other party for such loss or damage. Each party shall obtain any special
endorsements, if required by the insurer, whereby the insurer waives its right
of subrogation against the other party hereto. The provisions of this
Subparagraph 8.E. shall not apply in those instances in which the waiver of
subrogation would cause either party's insurance coverage to be voided or
otherwise made uncollectible; provided, such party has afforded the other party
at least thirty (30) days prior written notice of such fact and a period of at
least thirty (30) days has elapsed after delivery of such notice without
identification of alternative, reasonably equivalent insurance that can be
obtained without a voiding provision based on this waiver of subrogation.
9. Utilities. Tenant shall pay for all water, gas, light, heat, power,
electricity, telephone, trash pick-up, sewer charges, and all other services
supplied to or consumed on the Premises, and all taxes and surcharges thereon.
11
18
10. Repairs and Maintenance.
A. Landlord's Repairs. Subject to the provisions of Paragraphs
14 and 15 and the Improvement Agreement, Landlord, at its expense, shall keep
and maintain the exterior walls and the structural elements of the Buildings in
good order and repair. Landlord shall not, however, be required to maintain,
repair or replace the interior surface of exterior walls, nor shall Landlord be
required to maintain, repair or replace windows, doors, skylights or plate
glass. Landlord shall not be in default because it fails to make repairs under
this Subparagraph 10.A. until a reasonable time after receipt of written notice
from Tenant of the need for such repairs. Notwithstanding the foregoing but
subject to Subparagraph 8.E., Tenant shall reimburse Landlord, as Additional
Rent, within fifteen (15) days after receipt of billing, for the cost of
maintenance and repairs of the exterior walls and structural elements of the
Buildings to the extent such maintenance or repair is required because of the
negligence or willful misconduct of Tenant or its Agents, except as otherwise
provided in Subparagraph 8.E. As used herein, the term "STRUCTURAL ELEMENTS OF
THE BUILDINGS" shall mean and be limited to the foundations, footings, floor
slab (but not flooring), roof structure (but not roofing or roof membrane), load
bearing walls and structural portion of any second floor. If (a) repairs are
required to be made by Landlord pursuant to this Subparagraph 10.A., (b) the
failure to immediately make such repairs poses a threat of imminent danger to
people or property, and (c) after Landlord's receipt of notice from Tenant for
the need to make such repairs, Landlord does not immediately make such repairs,
then Tenant shall be allowed to make such repairs and Landlord shall reimburse
Tenant for the reasonable third party costs incurred by Tenant upon receipt of
written invoices for such repairs, lien releases from the third party making
such repairs and inspection of the repairs made by Tenant.
12
19
B. Tenant's Repairs.
(i) Except as expressly provided in Subparagraphs
8.E. and 10.A. above, Paragraphs 14 and 15 below and the Improvement Agreement,
Tenant shall, at its sole cost, keep and maintain the entire Premises and every
part thereof, including without limitation, the windows, window frames, plate
glass, glazing, skylights, truck doors, doors and all door hardware, the
interior walls and partitions, interior surfaces of exterior walls, carpets,
flooring, roofing, roof membrane, gutters, down spouts, the electrical,
plumbing, lighting, heating, ventilating and air conditioning systems and
equipment, and all areas outside the Buildings (including all landscaping,
irrigation systems, paving, driveways, parking areas, sidewalks, fences, signs
and exterior lighting) in good order, condition and repair. The term "repair"
shall include replacements, restorations and/or renewals when necessary as well
as painting. Except as expressly provided in Subparagraphs 8.E. and 10.A. above,
Paragraphs 14 and 15 below and the Improvement Agreement, Tenant's obligation
shall extend to all alterations, additions and improvements to the Premises, and
all fixtures and appurtenances therein and thereto. Tenant shall, at all times
during the Lease Term, have in effect a service contract for the maintenance of
the heating, ventilating and air conditioning ("HVAC") equipment with an HVAC
repair and maintenance contractor reasonably approved by Landlord. The HVAC
service contract shall provide for periodic inspection and servicing at least
once every three (3) months during the Lease Term, and Tenant shall provide
Landlord with a copy of such contract and all periodic service reports. Landlord
shall assign to Tenant for the Lease Term the benefit of all warranties
available to Landlord which would reduce the cost of performing the obligations
of Tenant to make repairs under this Subparagraph 10.B. Landlord shall cooperate
with Tenant in the enforcement of such warranties. Notwithstanding anything to
the contrary in this Lease, Tenant shall have no responsibility to perform or
construct, any repair, maintenance or improvement that Landlord is required to
perform pursuant to any other term of this Lease or the Improvement Agreement.
(ii) Should Tenant fail to commence to make repairs
required of Tenant hereunder within ten (10) days after written notice from
Landlord or should Tenant fail thereafter to diligently complete the repairs,
Landlord, in addition to all other remedies available hereunder or by Law and
without waiving any alternative remedies, may make the same, and in that event,
Tenant shall reimburse Landlord as Additional Rent for the cost of such
maintenance or repairs within ten (10) days of written demand by Landlord.
(iii) Notwithstanding anything to the contrary in
this Lease, any capital replacements to the Premises which are otherwise found
to be the obligation of Tenant under this Lease, whether or not required by law,
which are required by generally accepted accounting principles ("GAAP") to be
capitalized ("CAPITAL REPLACEMENTS") shall be made by and paid for by the
parties in accordance with the following:
(a) Tenant shall promptly undertake and
diligently complete, and Tenant shall be solely responsible for the cost of, all
Capital Replacements that have a cost
13
20
less than Three Hundred Thousand Dollars ($300,000).
(b) Upon Tenant's written notice to Landlord
for the need of any Capital Replacement which Landlord is required to make
pursuant to this Subparagraph 10.B.(iii)(b), Landlord shall promptly undertake
and diligently complete all Capital Replacements having a cost in excess of
Three Hundred Thousand Dollars ($300,000) ("LANDLORD'S CAPITAL REPLACEMENTS").
The cost of Landlord's Capital Replacements shall be borne by the parties as
follows:
(1) Tenant shall reimburse Landlord
for Tenant's Share of the Cost of Landlord's Capital Replacement within ten (10)
days following delivery to Tenant of reasonable documentation of the amount
owing by Tenant for completed work, which payments may be demanded by Landlord
of Tenant on a monthly basis as the work progresses. The "TENANT'S SHARE OF THE
COST OF LANDLORD'S CAPITAL REPLACEMENT," shall be equal to the total cost
reasonably incurred by Landlord to construct, permit and/or plan a Landlord's
Capital Replacement (the "CAPITAL COST") times a fraction, the numerator of
which is equal to the number of unexpired months in the then existing Lease Term
(without any consideration of Extended Terms that have not commenced), and the
denominator of which is equal to the useful life (expressed in months) of such
Landlord's Capital Replacement. The remainder of such cost shall be borne by
Landlord, subject to Subparagraphs 10.B.(iii)(b)(2) and 10.B.(iii)(b)(3), below.
(2) If the Lease Term is extended
by Tenant as herein permitted, then as a condition to each such extension and
within ten (10) days following Landlord's written demand therefor, Tenant shall
make an additional reimbursement of the Capital Cost of Landlord's Capital
Replacement in an amount equal to the Capital Cost times a fraction, the
numerator of which is equal to the lesser of (A) the useful life (expressed in
months) of such Landlord's Capital Replacement not subject to reimbursement
under Subparagraph 10.B.(iii)(b)(1) above and not subject to reimbursement under
this Subparagraph 10.B.(iii)(b)(2) with respect to a prior extension of the
Lease Term, or (B) the number of months in the extension period, and the
denominator of which is equal to the total useful life (expressed in months) of
such Landlord's Capital Replacement.
(3) If Landlord terminates this
Lease on account of an Event of Default by Tenant, as permitted by Section
13.B.(ii) below, then in addition to Landlord's other remedies, Tenant shall pay
to Landlord upon demand so much of the Capital Cost of Landlord's Capital
Replacement, which has not been theretofore reimbursed by Tenant to Landlord.
(iv) Landlord shall have no maintenance or repair
obligations whatsoever with respect to the Premises except as expressly provided
in this Lease and the Improvement Agreement. Tenant hereby expressly waives the
provisions of Subsection 1 of Section 1932 and Sections 1941 and 1942 of the
Civil Code of California and all rights to make repairs at the expense of
Landlord as provided in Section 1942 of said Civil Code; provided, Tenant shall
have the right to cure Landlord's defaults pursuant to the terms and conditions
of
14
21
Paragraph 38 hereof.
11. Alterations.
A. Limitations. Tenant shall not make, or suffer to be made,
any alterations, improvements or additions in, on, about or to the Premises or
any part thereof, without the prior written consent of Landlord (which consent
shall not be unreasonably withheld) and without a valid building permit issued
by the appropriate governmental authority; provided, however, Landlord's consent
shall not be required for interior non-structural alterations which (i) cost
less than Twenty Thousand Dollars ($20,000.00) per work of improvement and (ii)
cost less than Seventy Five Thousand Dollars ($75,000.00) for all alterations
made in any twelve (12) month period. As a condition to, and concurrently with,
the giving of such consent Landlord may require that Tenant agree to remove any
such alterations, improvements or additions at the termination of this Lease,
and to restore the Premises to their prior condition. Unless Landlord requires
that Tenant remove any such alteration, improvement or addition at the time that
Landlord provides its consent thereto, any alteration, addition or improvement
to the Premises, except movable furniture and trade fixtures not affixed to the
Premises, shall become the property of Landlord upon termination of the Lease
and shall remain upon and be surrendered with the Premises at the termination of
this Lease. Without limiting the generality of the foregoing, all heating,
lighting, electrical (including all wiring, conduit, outlets, drops, xxxx ducts,
main and subpanels), air conditioning, partitioning, drapery, and carpet
installations made by Tenant regardless of how affixed to the Premises, together
with all other additions, alterations and improvements that have become an
integral part of any of the Buildings, shall be and become the property of the
Landlord upon termination of the Lease, and shall not be deemed trade fixtures,
and shall remain upon and be surrendered with the Premises at the termination of
this Lease.
B. Tenant's Rights. All trade fixtures, movable furniture and
personal property installed in the Premises at Tenant's expense (collectively,
"TENANT'S PROPERTY") shall at all times remain Tenant's property and Tenant
shall be entitled to all depreciation, amortization and other tax benefits with
respect thereto, except for Tenant's Property which cannot be removed without
structural injury to the Premises. At any time during the Lease Term, Tenant may
remove Tenant's Property from the Premises, provided Tenant repairs all damage
caused by such removal. Landlord shall have no lien or other interest whatsoever
in any item of Tenant's Property or any portion thereof or interest therein,
located in the Premises or elsewhere, and Landlord hereby waives all such liens
and interests. Within ten (10) days following Tenant's written request, Landlord
shall execute documents in form reasonably acceptable to Tenant and Landlord to
evidence Landlord's waiver of any right, title, lien or interest in Tenant's
Property located in the Premises.
C. Alterations Required by Law. If, during the Lease Term, any
alteration, addition or change of any sort to all or any portion of the Premises
is required by Law, Tenant shall promptly make the same at its sole cost and
expense; provided, Tenant shall only be obligated to make alterations, additions
or changes required by Law to the "structural elements of
15
22
the Buildings" (as defined in Subparagraph 10.A. above), if such requirement is
triggered by (i) Tenant's particular use of the Premises, or (ii) Tenant's
alterations, improvements or additions in, on, about or to the Premises or any
part thereof; and if Landlord has performed its obligations under this Lease
with respect to the structural elements of the Buildings.
12. Acceptance of the Premises. By entry and taking possession of the
Premises pursuant to this Lease, Tenant accepts the Premises as being in good
and sanitary order, condition and repair and accepts the Premises in their
condition existing as of the date of such entry and Tenant further accepts the
Tenant Improvements to be constructed by Landlord, if any, as being completed in
accordance with the plans and specifications for such Tenant Improvements,
except for punch list items, and any express warranties by and obligations of
Landlord set forth in this Lease. Tenant acknowledges that neither the Landlord
nor Landlord's agents has made any representation or warranty as to the
suitability of the Premises to the conduct of Tenant's business. Any agreements,
warranties or representations not expressly contained herein shall in no way
bind either Landlord or Tenant, and Landlord and Tenant expressly waive all
claims for damages by reason of any statement, representation, warranty, promise
or agreement not contained in this Lease. This Lease constitutes the entire
understanding between the parties hereto and no addition to, or modification of,
any term or provision of this Lease shall be effective until set forth in a
writing signed by both Landlord and Tenant.
13. Default.
A. Events of Default. A breach of this Lease by Tenant shall
exist if any of the following events (hereinafter referred to as "EVENT OF
DEFAULT") shall occur:
(i) Default in the payment when due of any
installment of rent or other payment required to be made by Tenant hereunder,
where such default shall not have been cured within five (5) days after written
notice of such default is given to Tenant;
(ii) Tenant's failure to perform any other term,
covenant or condition contained in this Lease where such failure shall have
continued for twenty (20) days after written notice of such failure is given to
Tenant; provided, however, Tenant shall not be deemed in default if Tenant
commences to cure such failure within said twenty (20) day period and thereafter
diligently prosecutes such cure to completion;
(iii) Tenant vacates the Premises for sixty (60)
consecutive days and upon the expiration of such sixty (60) day period, Tenant
has failed to perform any term, covenant or condition contained in this Lease
(under such circumstances Tenant shall have no right to cure the default and
Landlord shall have no requirement to notify Tenant of the default except as
required by law);
(iv) Tenant's assignment of its assets for the
benefit of its creditors;
16
23
(v) The sequestration of, attachment of, or execution
on, any substantial part of the property of Tenant or on any property essential
to the conduct of Tenant's business, shall have occurred and Tenant shall have
failed to obtain a return or release of such property within thirty (30) days
thereafter, or prior to sale pursuant to such sequestration, attach ment or
levy, whichever is earlier;
(vi) Tenant or any guarantor of Tenant's obligations
hereunder shall commence any case, proceeding or other action seeking
reorganization, arrangement, adjustment, liquidation, dissolution or composition
of it or its debts under any Law relating to bankruptcy, insolvency,
reorganization or relief of debtors, or seek appointment of a receiver, trustee,
custodian, or other similar official for it or for all or any substantial part
of its property; or
(vii) Any case, proceeding or other action against
Tenant or any guarantor of Tenant's obligations hereunder shall be commenced
seeking to have an order for relief entered against it as debtor, or seeking
reorganization, arrangement, adjustment, liquidation, dissolution or composition
of it or its debts under any Law relating to bankruptcy, insolvency,
reorganization or relief of debtors, or seeking appointment of a receiver,
trustee, custodian or other similar official for it or for all or any
substantial part of its property, and such case, proceeding or other action (i)
results in the entry of an order for relief against it which is not fully stayed
within seven (7) business days after the entry thereof or (ii) remains
undismissed for a period of sixty (60) days.
Any notice given by Landlord in order to satisfy the requirements of
this Subparagraph 13.B. shall also satisfy the notice requirements of California
Code of Civil Procedure Section 1161 and all similar statutes regarding unlawful
detainer proceedings.
B. Remedies. Upon any Event of Default, Landlord shall have
the following remedies, in addition to all other rights and remedies provided by
law, to which Landlord may resort cumulatively, or in the alternative:
(i) Recovery of Rent. Landlord shall be entitled to
keep this Lease in full force and effect (whether or not Tenant shall have
abandoned the Premises) and to enforce all of its rights and remedies under this
Lease, including the right to recover rent and other sums as they become due,
plus interest at the Permitted Rate (as defined in Paragraph 31 below) as
therein provided.
(ii) Termination. Landlord may terminate this Lease
by giving Tenant written notice of termination in accordance with applicable
law. On the giving of the notice all of Tenant's rights in the Premises shall
terminate. Upon the giving of the notice of termination, Tenant shall surrender
and vacate the Premises in the condition required by Paragraph 32, and Landlord
may re-enter and take possession of the Premises and all the remaining
improvements or property and eject Tenant or any of Tenant's subtenants,
assignees or other person or persons claiming any right under or through Tenant
or eject some and not others or eject none. This Lease may also be terminated by
a judgment specifically providing for termination. Any
17
24
termination under this paragraph shall not release Tenant from the payment of
any sum then due Landlord or from any claim for damages or rent previously
accrued or then accruing against Tenant. In no event shall any one or more of
the following actions by Landlord constitute a termination of this Lease:
(a) maintenance and preservation of the
Premises;
(b) efforts to relet the Premises;
(c) appointment of a receiver in order to
protect Landlord's interest hereunder;
(d) consent to any subletting of the
Premises or assignment of this Lease by Tenant, whether pursuant to provisions
hereof concerning subletting and assignment or otherwise; or
(e) any other action by Landlord or
Landlord's agents intended to mitigate the adverse effects from any breach of
this Lease by Tenant.
(iii) Damages. In the event this Lease is terminated
pursuant to Subparagraph 13.B.(ii) above, or otherwise, Landlord shall be
entitled to damages in the following sums:
(a) the worth at the time of award of the
unpaid rent which has been earned at the time of termination; plus
(b) the worth at the time of award of the
amount by which the unpaid rent which would have been earned after termination
until the time of award exceeds the amount of such rental loss that Tenant
proves could have been reasonably avoided; plus
(c) the worth at the time of award of the
amount by which the unpaid rent for the balance of the term after the time of
award exceeds the amount of such rental loss that Tenant proves could be
reasonably avoided; and
(d) any other amount necessary to compensate
Landlord for all detriment proximately caused by Tenant's failure to perform
Tenant's obligations under this Lease, or which in the ordinary course of things
would be likely to result therefrom including, without limitation, the
following: (i) reasonable expenses for cleaning, repairing or restoring the
Premises to surrender condition; (ii) real estate broker's fees, advertising
costs and other expenses of reletting the Premises which are reasonably incurred
by Landlord and applicable to the period after termination of this Lease; (iii)
reasonable costs of carrying the Premises such as taxes and insurance premiums
thereon, utilities and security precautions not otherwise included in Additional
Rent; (iv) expenses in retaking possession of the Premises; and (v) reasonable
attorneys' fees and court costs.
18
25
(e) The "worth at the time of award" of the
amounts referred to in Subparagraphs (a) and (b) of this Subparagraph
13.B.(iii), is computed by allowing interest at the Permitted Rate. The "worth
at the time of award" of the amounts referred to in Subparagraph (c) of this
Subparagraph 13.B.(iii) is computed by discounting such amount at the discount
rate of the Federal Reserve Board of San Francisco at the time of award plus one
percent (1%). The term "rent" as used in this Paragraph 13 shall include all
sums required to be paid by Tenant to Landlord pursuant to the terms of this
Lease.
C. Waivers. Tenant hereby waives any right of redemption or
relief from forfeiture under the laws of the State of California, or under any
other present or future law, including the provisions of Sections 1174 and 1179
of the California Code of Civil Procedure.
14. Destruction.
A. Landlord's Duty to Restore. If the Improvements are damaged
by any peril after the Commencement Date of this Lease, Landlord shall restore
the Premises unless the Lease is terminated by Landlord pursuant to Subparagraph
14.B. or by Tenant pursuant to Subparagraph 14.C. All insurance proceeds
available from the property damage insurance carried by Landlord pursuant to
Subparagraph 8.C. shall be paid to and become the property of Landlord and shall
be used for the restoration of the Premises, unless this Lease is terminated
pursuant to Subparagraphs 14.B. or 14.C. or as otherwise required by Landlord's
Lender. If this Lease is terminated pursuant to either Subparagraphs 14.B. or
14.C., then all insurance proceeds available from the insurance required to be
carried by Tenant which covers loss to property that is Landlord's property or
would become Landlord's property on the termination of this Lease shall be paid
to and become the property of Landlord. If this Lease is not so terminated, then
Landlord shall be entitled to all such insurance proceeds and upon receipt of
such insurance proceeds (if the loss is covered by insurance) and the issuance
of all necessary governmental permits, Landlord shall commence and diligently
prosecute to completion the restoration of the Premises, to the extent then
allowed by Law, to substantially the same condition in which the Premises were
immediately prior to such damage. Landlord's obligation to restore shall be
limited to the Buildings and Tenant Improvements constructed by Landlord as they
existed as of the Commencement Date and to the extent Landlord receives
insurance proceeds, any Tenant Improvements as they existed as of the
Commencement Date which were paid for by Tenant, excluding any Tenant's Property
or Tenant Improvements paid for by Tenant to the extent Landlord does not
receive insurance proceeds for such Tenant Improvements.
B. Landlord's Right to Terminate. Landlord shall have the
option to terminate this Lease in the event any of the following occurs, which
option may be exercised only by delivery to Tenant of a written notice of
election to termi nate within thirty (30) days after the date of such damage:
(i) The Improvements are damaged by any peril either
(i) covered by the type of insurance Landlord is required to carry pursuant to
Subparagraph 8.C. or (ii) covered
19
26
by valid and collectible insurance actually carried by Landlord and in force at
the time of such damage or destruction, to such an extent that the estimated
restoration cost exceeds fifty percent (50%) of the then actual replacement cost
thereof.
(ii) The Improvements are damaged by any peril both
(i) not covered by the type of insurance Landlord is required to carry pursuant
to Subparagraph 8.C. and (ii) not covered by valid and collectible insurance
actually carried by Landlord and in force at the time of such damage or
destruction, to such an extent that the estimated restoration cost exceeds five
percent (5%) of the then actual replacement cost of the Improvements; provided,
however, that Landlord may not terminate this Lease pursuant to this
Subparagraph 14.B.(ii) if Tenant agrees in writing to pay the amount by which
the restoration cost exceed five percent (5%) of the replacement cost of the
Improvements and deposits with Landlord or provides other reasonable assurances
of payment (which assurances must be approved by Landlord's Lender) of an amount
equal to the estimated amount of such excess within thirty (30) days after
Landlord has notified Tenant with its election to terminate this Lease pursuant
to this Subparagraph 14.B.(ii).
(iii) The Improvements are damaged by any peril
during the last twelve (12) months of the Lease Term to such an extent that the
estimated cost to restore equals or exceeds an amount equal to six (6) times the
Monthly Installment of rent then due; provided, however, that Landlord may not
terminate this Lease pursuant to this Subparagraph 14.B.(iii) if Tenant, at the
time of such damage, has an express written option to further extend the term of
this Lease and Tenant exercises such option to so further extend the Lease Term
within fifteen (15) days following notice of Landlord's termination of this
Lease.
(iv) The Improvements are damaged by any peril and,
because of the Laws then in force, may not be restored at a cost less than or
equal to the available insurance proceeds and any amounts Tenant is required by
this Lease to pay or Tenant otherwise elects to pay, to substantially the same
condition in which it was prior to such damage.
C. Tenant's Right to Terminate. If the Improvements are
damaged by any peril and Landlord does not elect to terminate this Lease or is
not entitled to terminate this Lease pursuant to Subparagraph 14.B., then as
soon as reasonably practicable, Landlord shall furnish Tenant with the written
opinion of Landlord's architect or construction consultant as to when the
restoration work required of Tenant may be completed and the permits required
for such work can be obtained. Tenant shall have the option to terminate this
Lease in whole or in part as specified below in the event any of the following
occurs, which option may be exercised only by delivery to Landlord of a written
notice of election to terminate within fifteen (15) days after Tenant receives
from Landlord the estimate of the time needed to complete such restoration:
(i) If any Building is damaged by any peril and, in
the reasonable opinion of Landlord's architect or construction consultant, the
restoration of such Building cannot be substantially completed within two
hundred seventy (270) days after the date of the damage, then Tenant may
terminate the Lease as to such damaged Building only.
20
27
(ii) If any Building is damaged by any peril and all
permits required for the commencement of restoration are not obtained within
sixty (60) days beyond the time estimated by Landlord's architect or
construction consultant, or if following receipt of such permits the restoration
is not completed within sixty (60) days beyond the time estimated by Landlord's
architect or construction consultant as the required restoration time (provided
such time periods shall be extended by force majeure delays), then Tenant may
terminate this Lease with respect only to such damaged Building for which
permits are not timely obtained or which are not timely restored.
(iii) If any Building is damaged by any peril within
twelve (12) months of the last day of the Lease Term, and, in the reasonable
opinion of Landlord's architect or construction consultant, the restoration of
the Premises cannot be substantially completed within ninety (90) days after the
date of such damage, then Tenant may terminate this Lease with respect only to
such damaged Building.
(iv) If two (2) of the three (3) Buildings are
damaged by any peril and, in the reasonable opinion of Landlord's architect or
construction consultant, the restoration of all Buildings cannot be
substantially completed within two hundred seventy (270) days after the date of
the damage, Tenant may terminate the entire Lease.
D. Abatement of Rent. In the event of damage to the Premises
which does not result in the termination of this Lease, the Monthly Installment
of rent and Additional Rent shall be temporarily abated from the date of
inception of the loss until the damaged Building(s) are restored, in proportion
to the degree to which Tenant's use of the Premises is impaired by such damage.
Tenant shall not be entitled to any compensation from Landlord for loss of
Tenant's property or loss to Tenant's business caused by such damage or
restoration. Tenant hereby waives the provisions of Section 1932, Subdivision 2,
and Section 1933, Subdivision 4, of the California Civil Code, and the
provisions of any similar law, hereinafter enacted.
15. Condemnation.
A. Definition of Terms. For the purposes of this Lease, the
term (1) "TAKING" means a taking of the Premises or damage to the Premises
related to the exercise of the power of eminent domain and includes a voluntary
conveyance, in lieu of court proceedings, to any agency, authority, public
utility, person or corporate entity empowered to condemn property; (2) "TOTAL
TAKING" means the taking of the entire Premises or so much of the Premises as to
prevent or substantially impair the use thereof by Tenant for the uses herein
specified; (3) "PARTIAL TAKING" means a Taking which does not constitute a Total
Taking; (4) "DATE OF TAKING" means the date upon which the title to the
Premises, or a portion thereof, passes to and vests in the condemnor or the
effective date of any order for possession if issued prior to the date title
vests in the condemnor; and (5) "AWARD" means the amount of any award made,
consideration paid, or damages ordered as a result of a Taking.
B. Rights. The parties agree that in the event of a Taking all
rights (as
21
28
between them) in and to an Award shall be as set forth herein and Tenant shall
have no right to any Award except as set forth herein; provided, however, that
Tenant shall be entitled to any award for the taking of Tenant's Property.
C. Total Taking. In the event of a Total Taking during the
Lease Term (1) the rights of Tenant under the Lease and the leasehold estate of
Tenant in and to the Premises shall cease and terminate as of the Date of
Taking; (2) Landlord shall refund to Tenant any prepaid rent and any unapplied
security deposit; (3) Tenant shall pay Landlord any unpaid rent or charges due
Landlord under the Lease, each prorated as of the Date of Taking; (4) Tenant
shall receive from the Award those portions of the Award attributable to
Tenant's Property and for moving expenses of Tenant; and (5) the remainder of
the Award shall be paid to and be the property of Landlord.
D. Partial Taking. In the event of a Partial Taking during the
Lease Term (1) the rights of Tenant under the Lease and the leasehold estate of
Tenant in and to the portion of the Premises taken shall cease and terminate as
of the Date of Taking; (2) Landlord shall refund to Tenant any prepaid rent and
any unapplied security deposit relating to the portion of the Premises taken
based on a square footage basis; (3) Tenant shall pay Landlord any unpaid rent
or charges due Landlord under the Lease for the portion of the Premises taken,
each prorated as of the Date of Taking; (4) from and after the Date of Taking
the Monthly Installment of rent shall be an amount equal to the product obtained
by multiplying the Monthly Installment of rent immediately prior to the Taking
by a fraction, the numerator of which is the number of square feet contained in
the Building after the Taking and the denominator of which is the number of
square feet contained in the Building prior to the Taking; (5) Tenant shall
receive from the Award those portions of the Award attributable to Tenant's
Property and for moving expenses of Tenant; and (6) the remainder of the Award
shall be paid to and be the property of Landlord.
16. Mechanics' Lien. Tenant shall (A) pay for all labor and services
performed for, materials used by or furnished to, Tenant or any contractor
employed by Tenant with respect to the Premises; (B) indemnify, defend, protect
and hold Landlord and the Premises harmless and free from any liens, claims,
liabilities, demands, encumbrances, or judgments created or suffered by reason
of any labor or services performed for, materials used by or furnished to,
Tenant or any contractor employed by Tenant with respect to the Premises; (C)
give notice to Landlord in writing five (5) days prior to employing any laborer
or contractor to perform services related to, or receiving materials for use
upon the Premises; and (D) permit Landlord to post a notice of nonresponsibility
in accordance with the statutory requirements of California Civil Code Section
3094 or any amendment thereof. In the event Tenant is required to post an
improvement bond with a public agency in connection with the above, Tenant
agrees to include Landlord as an additional obligee.
17. Inspection of the Premises. Tenant shall permit Landlord and its
agents to enter the Premises at any reasonable time for the purpose of
inspecting the same, performing Landlord's maintenance and repair
responsibilities (upon 24 hour prior notice except in an emergency), posting a
notice of non-responsibility for alterations, additions or repairs and at any
22
29
time within two hundred seventy (270) days prior to expiration of this Lease, to
place upon the Premises, ordinary "For Lease" or "For Sale" signs.
18. Compliance with Laws. Tenant shall, at its own cost, comply with
all of the requirements of all municipal, county, state and federal authorities
now in force, or which may hereafter be in force, pertaining to Tenant's use and
occupancy of the Premises, and shall faithfully observe all municipal, county,
state and federal law, statutes or ordinances now in force or which may
hereafter be in force pertaining to Tenant's use and occupancy of the Premises.
The judgment of any court of competent jurisdiction or the admission of Tenant
in any action or proceeding against Tenant, whether Landlord be a party thereto
or not, that Tenant has violated any such ordinance or statute in the use and
occupancy of the Premises shall be conclusive of the fact that such violation by
Tenant has occurred. Tenant shall indemnify, protect, defend, and hold Landlord
harmless against any loss, expense, damage, attorneys' fees or liability to the
extent arising out of the failure of Tenant to comply with any applicable law,
except to the extent such failure of Tenant to comply with any applicable law is
caused by the negligence or willful misconduct of Landlord or its Agents.
19. Subordination. The following provisions shall govern the
relationship of this Lease to any underlying lease, mortgage or deed of trust
which now or hereafter affects the Premises or Landlord's interest or estate
therein and any renewal, modification, consolidation, replacement, or extension
thereof (a "SECURITY INSTRUMENT").
A. Priority. This Lease is subject and subordinate to all
Security Instruments existing as of the Commencement Date. However, if any
Lender so requires, this Lease shall become prior and superior to any such
Security Instrument. Landlord, as a condition to Tenant's obligations under this
Lease, shall obtain a recognition and non-disturbance agreement from all
existing lienholders in form reasonably acceptable to Tenant and Landlord's
Lender.
B. Subsequent Security Instruments. At Landlord's election,
this Lease shall become subject and subordinate to any Security Instrument
created after the Commencement Date, provided that the Lender holding such
Security Agreement agrees that in the event of foreclosure of the Security
Instrument in question, such Lender shall recognize the tenancy of Tenant on the
terms and conditions contained in this Lease so long as no Event of Default (as
defined in Paragraph 13.A. hereof) exists on the date such person acquires the
Premises. Notwithstanding such subordination, Tenant's right to quiet possession
of the Premises shall not be disturbed so long as no Event of Default exists on
the date such person acquires the Premises, unless this Lease is otherwise
terminated pursuant to its terms.
C. Documents. Tenant shall execute any reasonable document or
instrument required by Landlord or any Lender to make this Lease either prior or
subordinate to a Security Instrument, which may include such other matters as
the Lender customarily and reasonably requires in connection with such
agreements, including provisions that the Lender not be liable for (1) the
return of the Security Deposit unless the Lender receives it from Landlord, and
(2) any defaults on the part of Landlord occurring prior to the time that the
Lender takes possession of
23
30
the Premises in connection with the enforcement of its Security Instrument.
Tenant's failure to execute any such document or instrument within ten (10) days
after written demand therefor shall constitute a default by Tenant. Tenant's
obligation to execute and deliver any subordination agreement to any future
Lender shall be conditioned upon such Lender agreeing that in the event of
foreclosure of the mortgage or termination of the ground lease in question, such
Lender shall recognize the tenancy of Tenant on the terms and conditions
contained in this Lease as long as no Event of Default exists on the date such
person acquires the Premises.
D. Tenant's Attornment. Subject to the recognition obligations
under Subparagraphs 19.B. and 19.C. above, Tenant shall attorn (1) to any
purchaser of the Premises at any foreclosure sale or private sale conducted
pursuant to any Security Instrument encumbering the Premises; (2) to any grantee
or transferee designated in any deed given in lieu of foreclosure; or (3) to the
lessor under any underlying ground lease should such ground lease be terminated.
20. Holding Over. This Lease shall terminate without further notice at
the expiration of the Lease Term. Any holding over by Tenant after expiration
shall not constitute a renewal or extension or give Tenant any rights in or to
the Premises except as expressly provided in this Lease. Any holding over after
the expiration without the consent of Landlord shall be construed to be a
tenancy from month to month, at one hundred fifty percent (150%) of the monthly
rent for the last month of the Lease Term, and shall otherwise be on the terms
and conditions herein specified insofar as applicable.
21. Notices. Any notice required or desired to be given under this
Lease shall be in writing with copies directed as indicated below and shall be
personally served or given by facsimile (with receipt confirmed by telephone),
personal delivery, mail or by prepaid next-business day courier. Personal
delivery, mail and facsimile transmittal shall be effective when received or
delivery is refused by the party. Any notice given by courier shall be deemed to
have been given on the next business day after the time such notice was sent,
addressed to the party to be served with a copy as indicated herein at the last
address given by that party to the other party under the provisions of this
paragraph. At the date of execution of this Lease, the address of Landlord is:
South Bay Development Company, Inc.
000 Xxxxxxxx Xxxxxx
Xxxxxxxx, Xxxxxxxxxx 00000
Attn: Xx. Xxxxx Xxxxxx
With a copy to:
South Bay/San Xxxxx Associates
c/o AEW Real Estate Advisors, Inc.
000 Xxxxxxxx Xxxxxx
Xxxxxx, Xxxxxxxxxxxxx 00000
Attn: Xx. Xxxxxxxxxxx Xxxxxxxx
24
31
and the address of Tenant is:
Auspex Systems, Inc.
0000 Xxxxx Xxxxxxx Xxxxxxx
Xxxxx Xxxxx, Xxxxxxxxxx 00000
Attn: General Counsel
After the Commencement Date, the address of Tenant will be at the Premises.
22. Attorneys' Fees. In the event either party shall bring any action
or legal proceeding for damages for any alleged breach of any provision of this
Lease, to recover rent or possession of the Premises, to terminate this Lease,
or to enforce, protect or establish any term or covenant of this Lease or right
or remedy of either party, the prevailing party shall be entitled to recover as
a part of such action or proceeding, reasonable attorneys' fees and court costs,
including attorneys' fees and costs for appeal, as may be fixed by the court or
jury. The term "prevailing party" shall mean the party who received
substantially the relief requested, whether by settlement, dismissal, summary
judgment, judgment, or otherwise.
23. Subleasing and Assignment.
A. Landlord's Consent Required. Tenant's interest in this
Lease is not assignable, by operation of Law or otherwise, nor shall Tenant have
the right to sublet the Premises, transfer any interest of Tenant therein or
permit any use of the Premises by another party, without the prior written
consent of Landlord to each such assignment, subletting, transfer or use, which
consent Landlord agrees not to withhold unreasonably subject to the provisions
of Subparagraph 23.C. below. A consent to one assign ment, subletting, occupancy
or use by another party shall not be deemed to be a consent to any subsequent
assignment, subletting, occupancy or use by another party. Any assignment or
subletting without such consent shall be void and shall, at the option of
Landlord, terminate this Lease. Landlord's waiver or consent to any assignment
or subletting hereunder shall not relieve Tenant from any obligation under this
Lease unless the consent shall so provide.
B. Transferee Information Required. If Tenant desires to
assign its interest in this Lease or sublet the Premises, or transfer any
interest of Tenant therein, or permit the use of the Premises by another party
(hereinafter collectively referred to as a "TRANSFER"), Tenant shall give
Landlord at least twenty (20) business days prior written notice of the proposed
Transfer and of the terms of such proposed Transfer, including, but not limited
to, the name and legal composition of the proposed transferee, a financial
statement of the proposed transferee, the nature of the proposed transferee's
business to be carried on in the Premises (including a list of the type and
quantities of all Hazardous Materials to be used by the transferee on the
Premises), the payment to be made or other consideration to be given to Tenant
on account of the Transfer, and such other pertinent information as may be
reasonably requested by Landlord, all in sufficient detail to enable Landlord to
evaluate the proposed Transfer and the prospective
25
32
transferee.
C. Landlord's Rights. It is the intent of the parties hereto
that this Lease shall confer upon Tenant only the right to use and occupy the
Premises, and to exercise such other rights as are conferred upon Tenant by this
Lease. The parties agree that this Lease is not intended to have a bonus value
nor to serve as a vehicle whereby Tenant may profit by a future Transfer of this
Lease or the right to use or occupy the Premises as a result of any favorable
terms contained herein, or future changes in the market for leased space. It is
the intent of the parties that any such bonus value that may attach to this
Lease shall be and remain the exclusive property of Landlord, except as provided
in Subparagraph 23.C.(ii) below. In the event Tenant seeks to Transfer its
interest in this Lease or the Premises, Landlord shall have the following
options, which shall be exercised by Landlord, within twenty (20) business days
of Landlord receiving all of the information regarding the Transfer that is
required under Subparagraph 23.B., at Landlord's sole choice without limiting
Landlord in the exercise of any other right or remedy which Landlord may have by
reason of such proposed Transfer:
(i) In the event of a Transfer constituting either an
assignment of the entire Lease or a sublease of substantially all of the
Premises for all or substantially all of the balance of the Lease Term, Landlord
may elect to terminate this Lease effective as of the proposed effective date of
the proposed Transfer and release Tenant from any further liability hereunder
accruing after such termination date by giving Tenant written notice of such
termination within fifteen (15) days after receipt by Landlord of Tenant's
notice of intent to Transfer as provided above. If Landlord makes such election
to terminate this Lease, Tenant shall surrender the Premises, in accordance with
Paragraph 32, on or before the effective termination date; or
(ii) Landlord may consent to the proposed Transfer on
the condition that Tenant agrees to pay to Landlord, as additional rent, fifty
percent (50%) of any and all rents or other consideration (including key money)
received by Tenant from the transferee by reason of such Transfer in excess of
the rent payable by Tenant to Landlord under this Lease (after reimbursement to
Tenant of any brokerage commissions, attorneys' fees and advertising expenses
incurred by Tenant in connection with the Transfer, and any tenant improvement
costs related to such Transfer that are incurred by Tenant). Tenant expressly
agrees that the foregoing is a reasonable condition for obtaining Landlord's
consent to any Transfer;
(iii) Landlord may consent to the proposed Transfer
on the condition that if such Transfer is an assignment that Landlord in its
sole and absolute discretion shall determine whether such Transfer shall include
the right to exercise the Options to extend the Lease Term;
(iv) Landlord may withhold its consent in its sole
and absolute discretion to the proposed Transfer if the Transfer is a sublease
and the term of the such sublease extends beyond the then existing Lease Term
(the "then existing Lease Term" shall not include any unexercised options to
extend the Lease Term); or
26
33
(v) Landlord may reasonably withhold its consent to
the proposed Transfer.
If Landlord agrees to consent to the proposed Transfer pursuant to Subparagraphs
23.C.(ii) or 23.C.(iii), Landlord shall provide such consent on Landlord's form
within ten (10) business days of Landlord electing such option and receiving the
final version of the document evidencing the Transfer.
D. Permitted Transfers. Notwithstanding the foregoing, Tenant
may, without Landlord's prior written consent and without providing to Landlord
the option described in Subparagraph 23.C.(i) above, assign its interest in the
Lease or sublet the Premises or a portion thereof to (i) a subsidiary,
affiliate, division or corporation controlled by or under common control with
Tenant; (ii) a successor corporation related to Tenant by merger, consolidation,
non-bankruptcy reorganization or government action; or (iii) a purchaser of
substantially all of the Tenant's assets; provided that, in each instance
described above, (a) each assignee assumes the obligations of Tenant under this
Lease and each sublessee agrees to abide by this Lease in a written instrument
delivered to Landlord; (b) Tenant as transferor remains liable as a primary
obligor for the obligations of the tenant under this Lease; and (c) the
financial strength of the transferee tenant is no less than Tenant's financial
strength as of the Commencement Date or the date of such Transfer, whichever is
greater. Additionally, Tenant may, without Landlord's prior written consent,
sublease one (1) of the Buildings prior to taking occupancy thereof, provided
that (x) the sublessee agrees to abide by the obligations of Tenant under this
Lease in a written instrument delivered to Landlord; (y) Tenant as transferor
remains liable as a primary obligor for the obligations of the tenant under this
Lease; and (z) the term of the sublease does not exceed thirty-six (36) months
from the Commencement Date.
24. Successors. The covenants and agreements contained in this Lease
shall be binding on and inure to the benefit of the parties hereto and on their
respective heirs, successors and assigns (to the extent the Lease is
assignable).
25. Mortgagee Protection. In the event of any default on the part of
Landlord, Tenant will give notice by registered or certified mail to any
beneficiary of a deed of trust or mortgagee of a mortgage encumbering the
Premises, whose address shall have been previously furnished to Tenant in
writing by Landlord. Such beneficiary or mortgagee shall have the right to cure
Landlord's default and so long as such beneficiary or mortgagee is making
reasonable efforts to cure Landlord's default, including, but not limited to,
obtaining possession of the Premises by power of sale or judicial foreclosure,
if such should prove necessary to effect a cure, Tenant shall not have the right
to terminate this Lease.
26. Estoppel Certificate. Tenant and Landlord agree within ten (10)
days following request by the other party to (A) execute and deliver to other
party any documents, including estoppel certificates presented to a party by the
other party, (1) certifying that this Lease is unmodified, or if modified,
indicating the modifications, and in full force and effect and the date
27
34
to which the rent and other charges are paid in advance, if any, and (2)
acknowledging that there are not, to such party's knowledge, any uncured
defaults on the part of other party hereunder, or specifying the defaults, if
any, and (3) evidencing the status of the Lease as may be reasonably required
either by a lender making a loan to Landlord or to Tenant to be secured by a
deed of trust or mortgage covering the Premises or a purchaser of the Premises
from Landlord, and (B) Tenant agrees to deliver to Landlord the financial
statement of Tenant with an opinion of a certified public accountant, including
a balance sheet and profit and loss statement, for the last completed fiscal
year all prepared in accordance with generally accepted accounting principles
consistently applied. Tenant's failure to deliver an estoppel certificate within
ten (10) days following a request by Landlord shall be an Event of Default under
this Lease. Landlord's failure to deliver an estoppel certificate within ten
(10) days following a request by Tenant shall be an event of default under this
Lease.
27. Surrender of Lease Not Merger. The voluntary or other surrender of
this Lease by Tenant, or a mutual cancellation thereof, shall not work a merger
and shall, at the option of Landlord, terminate all or any existing subleases or
subtenants, or operate as an assignment to Landlord of any or all such subleases
or subtenants.
28. Waiver. The waiver by Landlord or Tenant of any breach of any term,
covenant or condition herein contained shall not be deemed to be a waiver of
such term, covenant or condition or any subsequent breach of the same or any
other term, covenant or condition herein contained. Any waiver shall be in
writing and signed by both Landlord and Tenant.
29. General.
A. Captions. The captions and paragraph headings used in this
Lease are for the purposes of convenience only. They shall not be construed to
limit or extend the meaning of any part of this Lease, or be used to interpret
specific sections. The word(s) enclosed in quotation marks shall be construed as
defined terms for purposes of this Lease. As used in this Lease, the masculine,
feminine and neuter and the singular or plural number shall each be deemed to
include the other whenever the context so requires.
B. Definition of Landlord. The term Landlord as used in this
Lease, so far as the covenants or obligations on the part of Landlord are
concerned, shall be limited to mean and include only the owner at the time in
question of the fee title of the Premises, and in the event of any transfer or
transfers of the title of such fee, the Landlord herein named (and in case of
any subsequent transfers or conveyances, the then grantor) shall be
automatically freed and relieved of all liability with respect to performance of
any covenants or obligations on the part of Landlord contained in this Lease to
be performed after the date of such transfer or conveyance which are assumed in
writing by the transferee; provided that any funds in the hands of Landlord or
the then grantor at the time of such transfer, in which Tenant has an interest,
shall be turned over to the grantee. It is intended that the covenants and
obligations contained in this Lease on the part of Landlord shall, subject as
aforesaid, be binding upon each Landlord, its heirs, personal representatives,
successors and assigns only with respect to the obligations of Landlord arising
28
35
during its respective period of ownership.
C. Time of Essence. Time is of the essence for the performance
of each term, covenant and condition of this Lease.
D. Severability. In case any one or more of the provisions
contained herein, except for the payment of rent, shall for any reason be held
to be invalid, illegal or unenforceable in any respect, such invalidity,
illegality or unenforceability shall not affect any other provision of this
Lease, but this Lease shall be construed as if such invalid, illegal or
unenforceable provision had not been contained herein. This Lease shall be
construed and enforced in accordance with the laws of the State of California.
E. Quiet Enjoyment. Upon Tenant paying the rent for the
Premises and observing and performing all of the covenants, conditions and
provisions on Tenant's part to be observed and performed hereunder, Tenant shall
have quiet possession of the Premises for the entire term hereof subject to all
of the provisions of this Lease.
F. Law. As used in this Lease, the term "LAW" or "LAWS" shall
mean any judicial decision, statute, constitution, ordinance, resolution,
regulation, rule, administrative order, or other requirement of any government
agency or authority having jurisdiction over the parties to this Lease or the
Premises or both, in effect at the Commencement Date of this Lease or any time
during the Lease Term, including, without limitation, any regulation, order, or
policy of any quasi-official entity or body (e.g., board of fire examiners,
public utility or special district).
G. Agent. As used in this Lease, the term "AGENT" shall mean,
with respect to either Landlord or Tenant, its respective agents, employees,
contractors (and their subcontractors), and invitees (and in the case of Tenant,
its subtenants).
H. Lender. As used in this Lease, the term "LENDER" shall mean
any beneficiary, mortgagee, secured party or other holder of any deed of trust,
mortgage or other written security device or agreement affecting Landlord's
interest in the Premises.
I. Force Majeure. Any prevention, delay or stoppage due to
strikes, lock-outs, inclement weather, labor disputes, inability to obtain
labor, materials, fuels or reasonable substitutes therefor, governmental
restrictions, regulations, controls, action or inaction, civil commotion, fire
or other acts of God, and other causes beyond the reasonable control of the
party obligated to perform (except financial inability) shall excuse the
performance, for a period equal to the period of any said prevention, delay or
stoppage, or any obligation hereunder except the obligation of Tenant to pay
rent or any other sums due hereunder.
30. Sign. Tenant shall not place or permit to be placed any sign or
decoration on the Parcel or the exterior of any of the Buildings without the
prior written consent of Landlord, which consent shall not be unreasonably
withheld or delayed. Tenant, upon written notice by
29
36
Landlord, shall immediately remove any sign or decoration that Tenant has placed
or permitted to be placed on the Parcel or the exterior of any of the Buildings
without the prior written consent of Landlord, and if Tenant fails to so remove
such sign or decoration within five (5) days after Landlord's written notice,
Landlord may enter upon the Premises and remove said sign or decoration and
Tenant agrees to pay Landlord, as additional rent upon demand, the cost of such
removal. At the termination of this Lease, Tenant shall remove any sign which it
has placed on the Parcel or any of the Buildings and shall repair any damage
caused by the installation or removal of such sign.
31. Interest on Past Due Obligations. Any Monthly Installment of rent
due from Tenant, or any other sum due under this Lease from Tenant, which is
received by Landlord after the date ten (10) days following the date written
notice is given by Landlord to Tenant that such sum has not been paid when due,
shall bear interest from said due date until paid, at an annual rate equal to
the lower of (the "PERMITTED RATE"): (1) twelve percent (12%); or (2) five
percent (5%) plus the rate established by the Federal Reserve Bank of San
Francisco, as of the twenty-fifth (25th) day of the month immediately preceding
the due date, on advances to member banks under Sections 13 and 13(a) of the
Federal Reserve Act, as now in effect or hereafter from time to time amended.
Payment of such interest shall not excuse or cure any default by Tenant. In
addition, Tenant shall pay all costs and attorneys' fees reasonably incurred by
Landlord in collection of such amounts.
32. Surrender of the Premises. On the last day of the term hereof, or
on the sooner termination of this Lease, Tenant shall surrender the Premises to
Landlord in their condition existing as of the Commencement Date of this Lease,
except for (A) ordinary wear and tear; (B) acts of God; (C) condemnation; (D)
Hazardous Materials which Tenant is not responsible for pursuant to this Lease;
and (E) all alterations, improvements or additions which Tenant is not required
to remove pursuant to this Lease. Tenant shall surrender the Premises with all
originally painted interior walls washed, and other interior walls cleaned, and
repaired or replaced, the air conditioning and heating equipment serviced and
repaired by a reputable and licensed service firm as required by Paragraph 10.B.
hereof, all floors cleaned and waxed, all to the reasonable satisfaction of
Landlord. Tenant shall remove all of Tenant's Property from the Premises, and
all property not so removed shall be deemed abandoned by Tenant. Tenant, at its
sole cost, shall repair any damage to the Premises caused by the removal of
Tenant's Property, which repair shall include, without limitation, the patching
and filling of holes and repair of structural damage. If the Premises are not so
surrendered at the termination of this Lease, Tenant shall indemnify, defend,
protect and hold Landlord harmless from and against loss or liability resulting
from delay by Tenant in so surrendering the Premises including without
limitation, any claims made by any succeeding tenant or losses to Landlord due
to lost opportunities to lease to succeeding tenants.
33. Authority. The undersigned parties hereby warrant that they have
proper authority and are empowered to execute this Lease on behalf of Landlord
and Tenant, respectively.
34. CC&Rs. This Lease is made subject to all matters of public record
affecting title to the property of which the Premises are a part as described in
the Preliminary Title Report
30
37
dated October 2, 1996, prepared by Santa Xxxxx Land Title Company, Order No.
00121233, a copy of which is attached hereto as Exhibit "G" (the "TITLE
REPORT"). Tenant shall abide by and comply with all private conditions,
covenants and restrictions of public record now or hereafter affecting the
Premises as described on Exhibit "H" with reference to the Title Report
("CC&RS"), except as may be otherwise provided in Exhibit "H". Landlord
represents and warrants that to its actual knowledge no violation of the CC&Rs
exists as of the date of this Lease. During the Lease Term, Landlord shall
promptly notify Tenant of any modification to the CC&Rs.
35. Brokers. The parties represent and warrant to each other that they
have not dealt with any broker respecting this transaction other than
Xxxxxx/Xxxxx Corporate Real Estate Services (the "BROKER") and hereby agree to
indemnify and hold each other harmless from and against any brokerage commission
or fee, obligation, claim or damage (including attorneys' fees) paid or incurred
respecting any broker claiming through the other party or with which/whom the
other party has dealt. Landlord shall pay commission owing to the Broker
pursuant to a separate agreement between Landlord and the Broker.
36. Limitation on Landlord's Liability36. Limitation on Landlord's
Liability. Tenant, for itself and its successors and assigns (to the extent this
Lease is assignable), hereby agrees that in the event of any actual, or alleged,
breach or default by Landlord under this Lease that:
A. Tenant's sole and exclusive remedy and recourse against
Landlord shall be as against Landlord's interest in the Premises and this Lease;
B. No partner of Landlord shall be sued or named as a party in
a suit or action (except as may be necessary to secure jurisdiction of the
partnership) for the breach of any obligation of Landlord or the act or omission
of Landlord or its Agents;
C. No service of process shall be made against any partner of
Landlord with respect to any claim arising under or out of this Lease (except as
may be necessary to secure jurisdiction of the partnership);
D. No partner of Landlord shall be required to answer or
otherwise plead to any service of process with respect to any claim arising
under or out of this Lease (except as may be necessary to secure jurisdiction of
the partnership);
E. No judgment will be taken against any partner of Landlord
for the breach of any obligation of Landlord or the act or omission of Landlord
or its Agents;
F. Any such judgment taken against any partner of Landlord may
be vacated and set aside at any time nunc pro tunc;
G. No writ of execution will ever be levied against the assets
of any partner of Landlord for a judgment based on any breach of a Landlord's
obligations under this Lease or any
31
38
act or omission of Landlord; and
H. The covenants and agreements of Tenant set forth in this
Paragraph 36 shall be enforceable by Landlord and any partner of Landlord.
37. Hazardous Material.
A. Definitions. As used herein, the term "HAZARDOUS MATERIAL"
shall mean any substance: (i) the presence of which requires investigation or
remediation under any federal, state or local statute, regulation, ordinance,
order, action, policy or common law; (ii) which is or becomes defined as a
"hazardous waste," "hazardous substance," pollutant or contaminant under any
federal, state or local statute, regulation, rule or ordinance or amendments
thereto including, without limitation, the Comprehensive Environmental Response,
Compensation and Liability Act (42 U.S.C. Section 9601 et seq.) and/or the
Resource Conservation and Recovery Act (42 U.S.C. Section 6901 et seq.); (iii)
which is toxic, explosive, corrosive, flammable, infectious, radioactive,
carcinogenic, mutagenic, or otherwise hazardous and is or becomes regulated by
any governmental authority, agency, department, commission, board, agency or
instrumentality of the United States, the State of California or any political
subdivision thereof; (iv) the presence of which on the Premises causes or
threatens to cause a nuisance upon the Premises or to adjacent properties or
poses or threatens to pose a hazard to the health or safety of persons on or
about the Premises; (v) the presence of which on adjacent properties could
constitute a trespass by Landlord or Tenant; (vi) without limitation which
contains gasoline, diesel fuel or other petroleum hydrocarbons; (vii) without
limitation which contains polychlorinated biphenyls (PCBs), asbestos or urea
formaldehyde foam insulation; or (viii) without limitation radon gas.
B. Landlord's Obligation. Except for the Existing
Environmental Condition (as defined in Subparagraph 37.L. hereof), Landlord has
no actual knowledge, without any duty to make investigation, of any Hazardous
Materials present in the soil or groundwater of the Parcel. Landlord, at its
sole cost, shall comply with all Laws which impose liability or responsibility
upon either Landlord or Tenant to investigate, remediate or otherwise take any
action with respect to the Existing Environmental Condition; provided, however,
that this covenant shall not require Landlord to perform any obligation Tenant
has under this Paragraph 37. Subject to Subparagraph 8.E., Landlord shall
indemnify, defend, protect and hold Tenant harmless from and against all
liabilities, claims, penalties, fines, response costs and other expenses
(including reasonable attorneys' fees) which result from Landlord's failure to
timely perform the obligation stated in the immediate preceding sentence.
C. Permitted Use. Subject to the compliance by Tenant with the
provisions of Subparagraphs D, E, F, G, I, J and K below, Tenant shall be
permitted to use and store on the Premises those Hazardous Materials listed in
Exhibit "E" attached hereto, in the quantities set forth in Exhibit "E" and such
other Hazardous Materials approved by Landlord in writing.
32
39
D. Hazardous Materials Management Plan.
(i) Prior to Tenant or its subtenant using, handling,
transporting or storing any Hazardous Material at or about the Premises
(including, without limitation, those listed in Exhibit "E" other than customary
quantities of janitorial and office supplies), Tenant shall submit to Landlord a
Hazardous Materials Management Plan ("HMMP") for Landlord's review and approval,
which approval shall not be unreasonably withheld. The HMMP shall describe: (aa)
the quantities of each material to be used, (bb) the purpose for which each
material is to be used, (cc) the method of storage of each material, (dd) the
method of transporting each material to and from the Premises and within the
Premises, (ee) the methods Tenant will employ to monitor the use of the material
and to detect any leaks or potential hazards, and (ff) any other information any
department of any governmental entity (city, state or federal) requires prior to
the issuance of any required permit for the Premises or during Tenant's
occupancy of the Premises. Landlord may, but shall have no obligation to review
and approve the foregoing information and HMMP, and such review and approval or
failure to review and approve shall not act as an estoppel or otherwise waive
Landlord's rights under this Lease or relieve Tenant of its obligations under
this Lease; provided that a failure to review and approve within a reasonable
time shall not be deemed a disapproval. If Landlord determines in good faith by
inspection of the Premises or review of the HMMP that the methods in use or
described by Tenant are not adequate in Landlord's good faith judgment to
prevent or eliminate the existence of environmental hazards, then Tenant shall
not use, handle, transport, or store such Hazardous Materials at or about the
Premises unless and until such methods are approved by Landlord in good faith
and added to an approved HMMP. Once approved by Landlord, Tenant shall strictly
comply with the HMMP and shall not change its use, operations or procedures with
respect to Hazardous Materials without submitting an amended HMMP for Landlord's
review and approval as provided above.
(ii) Tenant shall pay to Landlord when Tenant submits
an HMMP (or amended HMMP) the amount reasonably determined by Landlord to cover
all Landlord's costs and expenses reasonably incurred in connection with
Landlord's review of the HMMP which costs and expenses shall include, among
other things, all reasonable out-of-pocket fees of attorneys, architects, or
other consultants incurred by Landlord in connection with Landlord's review of
the HMMP. Landlord shall have no obligation to consider a request for consent to
a proposed HMMP unless and until Tenant has paid to Landlord its reasonable
estimate of all such costs and expenses to Landlord, and Tenant shall pay all
such costs and expenses to Landlord irrespective of whether Landlord consents to
such proposed HMMP. Tenant shall pay to Landlord on demand the excess, if any,
of such costs and expenses actually incurred by Landlord over the amount of such
costs and expenses actually paid by Tenant, and Landlord shall promptly refund
to Tenant the excess, if any, of such costs and expenses actually paid by Tenant
over the amount of such costs and expenses actually incurred by Landlord.
E. Use Restriction. Except as specifically allowed in
Subparagraph C above, Tenant shall not cause or permit any Hazardous Material to
be used, stored, generated, discharged, transported to or from, or disposed of
in or about the Premises, or any other land or
33
40
improvements in the vicinity of the Premises. Without limiting the generality of
the foregoing, Tenant, at its sole cost, shall comply with all Laws relating to
the storage, use, generation, transport, discharge and disposal by Tenant or its
Agents of any Hazardous Material. If the presence of any Hazardous Material on
the Premises (other than an Existing Environmental Condition) caused or
permitted by Tenant or its Agents results in contamination of the Premises or
any soil, air, ground or surface waters under, through, over, on, in or about
the Premises, Tenant, at its expense, shall promptly take all actions necessary
to return the Premises and/or the surrounding real property to the condition
existing prior to the appearance of such Hazardous Material to the extent
feasible and in all events, to a condition which complies with applicable
Environmental Law. In the event there is a release, discharge or disposal of or
contamination of the Premises by a Hazardous Material which is of the type that
has been stored, handled, transported or otherwise used or permitted by Tenant
or its Agents on or about the Premises (other than an Existing Environmental
Condition), Tenant shall have the burden of proving that such release,
discharge, disposal or contamination is not the result of the acts or omissions
of Tenant or its Agents.
F. Tenant Indemnity. Tenant shall defend, protect, hold
harmless and indemnify Landlord and its Agents and Lenders with respect to all
actions, claims, losses (including, diminution in value of the Premises), fines,
penalties, fees (including, but not limited to, attorneys' and consultants'
fees) costs, damages, liabilities, remediation costs, investigation costs,
response costs and other expenses arising out of, resulting from, or caused by
(i) any Hazardous Material used, generated, discharged, transported to or from,
stored, or disposed of by Tenant or its Agents in, on, under, over, through or
about the Premises and/or the surrounding real property or (ii) any disposal or
release of any Hazardous Material on the surface of the Premises occurring after
the Commencement Date and prior to the termination of this Lease that is not the
result of the negligent acts or wilful misconduct of Landlord or its Agents;
provided that in no event shall the foregoing create any liability in Tenant for
an Existing Environmental Condition. Tenant shall not suffer any lien to be
recorded against the Premises as a consequence of the disposal of any Hazardous
Material on the Premises by Tenant or its Agents, including any so called state,
federal or local "super fund" lien related to the "clean up" of any such
Hazardous Material in, over, on, under, through, or about the Premises.
G. Compliance. Tenant shall immediately notify Landlord, and
Landlord shall notify Tenant, of any inquiry, test, investigation, enforcement
proceeding by or against Tenant or the Premises concerning contamination of the
Premises caused by any Hazardous Material. Any remediation plan prepared by or
on behalf of Tenant must be submitted to Landlord prior to conducting any work
pursuant to such plan and prior to submittal to any applicable government
authority and shall be subject to Landlord's consent which consent shall not be
unreasonably withheld or delayed. Tenant acknowledges that Landlord, as the
owner of the Property, at its election, shall have the sole right to negotiate,
defend, approve and appeal any action taken or order issued with regard to any
Hazardous Material by any applicable governmental authority.
H. Assignment and Subletting. It shall not be unreasonable for
Landlord to
34
41
withhold its consent to any proposed assignment or subletting if (i) the
proposed assignee's or subtenant's anticipated use of the Premises involves the
storage, generation, discharge, transport, use or disposal of any Hazardous
Material (other than reasonable quantities of office supplies, warehouse
supplies and janitorial supplies that may contain Hazardous Materials) in a
manner which represents a risk to the health and safety of persons on or about
the Premises, and in Landlord's opinion, that risk is a material risk; (ii) if
the proposed assignee or subtenant has been required by any prior landlord,
lender or governmental authority to "clean up" or remediate any Hazardous
Material resulting from the negligence or affirmative actions of the proposed
assignee or subtenant within the last five (5) years; (iii) if the proposed
assignee or subtenant is subject to investigation or enforcement order or
proceeding by any governmental authority in connection with the use, generation,
discharge, transport, disposal or storage of any Hazardous Material resulting
from the negligence or affirmative actions of the proposed assignee or subtenant
within the last five (5) years.
I. Surrender. Upon the expiration or earlier termination of
the Lease, Tenant, at its sole cost, shall remove all Hazardous Materials from
the Premises that Tenant or its Agents introduced to the Premises. If Tenant
fails to so surrender the Premises, Tenant shall indemnify, protect, defend and
hold Landlord harmless from and against all damages to the extent resulting from
Tenant's failure to surrender the Premises as required by this Paragraph,
including, without limitation, any actions, claims, losses, liabilities, fees
(including, but not limited to, attorneys' and consultants' fees), fines, costs,
penalties, or damages in connection with the condition of the Premises
including, without limitation, damages occasioned by the inability to relet the
Premises or a reduction in the fair market and/or rental value of the Premises
by reason of the existence of any Hazardous Material that Tenant or its Agents
introduced in, on, over, under, through or around the Premises.
J. Right to Appoint Consultant. If Tenant or its Agents have
used Hazardous Materials (other than customary quantities of janitorial or
office supplies), Landlord shall have the right to appoint a consultant, at
Tenant's expense, to conduct an investigation to determine whether any Hazardous
Material is being used, generated, discharged, transported to or from, stored or
disposed of in, on, over, through, or about the Premises, in an inappropriate or
unlawful manner. If Tenant has violated any Law or covenant in this Lease
regarding the use, storage or disposal of Hazardous Materials on or about the
Premises, Tenant shall reimburse Landlord for the cost of such investigation.
Tenant, at its expense, shall comply with all reasonable recommendations of the
consultant or take other steps approved by Landlord required to conform Tenant's
use, storage or disposal of Hazardous Materials to the requirements of
applicable Law or to fulfill the obligations of Tenant hereunder.
K. Holding Over. If during the Lease Term, Tenant or any of
its Agents is required to take any action of any kind required or requested to
be taken by any governmental authority to clean-up, remove, remediate or monitor
any Hazardous Material (the presence of which is the result of the acts or
omissions of Tenant or its Agents and other than an Existing Environmental
Condition) and such action is not completed prior to the expiration or earlier
termination of the Lease, Tenant shall be deemed to have impermissibly held over
until such time
35
42
as such required action is completed, and Landlord shall be entitled to all
damages directly or indirectly incurred in connection with such holding over,
including without limitation, damages occasioned by the inability to re-let the
Premises or a reduction of the fair market and/or rental value of the Premises.
L. Existing Environmental Reports. Tenant hereby acknowledges
that it has received, read and reviewed the reports and test results described
in Exhibit "F" attached hereto and made a part hereof (the "EXISTING
ENVIRONMENTAL REPORTS"). The Hazardous Materials currently present in, on or
under the Premises or the soil, groundwater, surface water or air thereof, or
in, on, or under any property in the vicinity of the Premises, or the soil,
groundwater, surface water or air thereof, as described in the Existing
Environmental Reports are referred to herein as the "EXISTING ENVIRONMENTAL
CONDITION". Tenant shall keep the Existing Environmental Reports and all
information contained therein confidential, except Tenant shall be allowed to
disclose such information to Tenant's consultants and attorneys provided such
parties agree to keep the information confidential.
M. Provisions Survive Termination. The provisions of this
Paragraph 37 shall survive the expiration or termination of this Lease.
N. Controlling Provisions. The provisions of this Paragraph 37
are intended to govern the rights and liabilities of the Landlord and Tenant
under this Lease respecting Hazardous Materials to the exclusion of any other
provisions in this Lease that might otherwise be deemed applicable. The
provisions of this Paragraph 37 shall be controlling with respect to any
provisions in this Lease that are inconsistent with this Paragraph 37.
38. Landlord's Default.
A. If Tenant believes Landlord has failed to perform or
provide any service or pay any sum which Tenant in good faith believes Landlord
is obligated to provide, perform or pay under this Lease, Tenant shall provide
Landlord with written notice thereof. If Landlord does not perform or provide
the required service or make such required payment within thirty (30) days after
receipt of Tenant's notice (or if such failure cannot be cured within such
thirty (30) day period, if Landlord does not promptly commence to provide or
cure the same and diligently pursue the same to completion), Tenant shall have
the right to provide, perform or pay the same. If Tenant, after such notice,
provides and performs such service or makes such payment and sends to Landlord a
written statement reflecting the reasonable costs for providing the same or the
amount paid and Landlord fails to pay the same within twenty (20) days after
receipt of such notice, Tenant shall have the right to seek and obtain damages
from Landlord.
B. In the event of any default by Landlord, Tenant's exclusive
remedies shall be an action for specific performance or an action for damages.
Tenant hereby waives the benefit of any laws granting it the right to terminate
this Lease or withhold rent on account of any Landlord default. Tenant waives
the provisions of Sections 1932(l), 1941 and 1942 of the California Civil Code
and any similar or successor law regarding Tenant's right to terminate this
36
43
Lease or to make repairs and deduct the expenses of such repairs from the rent
due under this Lease.
39. Condition to Effectiveness. The effectiveness of this Lease is
conditioned upon Landlord obtaining architectural approval by April 1, 1997 from
the City of Santa Xxxxx for the construction of the ninety eight thousand four
hundred thirty (98,430) square foot building described in the Lease Agreement
between Landlord and Tenant dated concurrently with this Lease. This condition
is for the benefit of Tenant and Tenant may waive this condition by written
notice to Landlord on or before April 1, 1997. If on or before April 1, 1997
this condition is neither fulfilled nor waived by Tenant, then this Lease shall
automatically terminate, Landlord shall return the Security Deposit to Tenant
and the parties shall have no further rights or obligations hereunder. If this
condition is fulfilled or waived by Tenant on or before April 1, 1997, then this
Lease shall continue in full force and effect. Landlord shall use good faith and
all reasonable efforts to obtain the architectural approval by April 1, 1997.
37
44
IN WITNESS WHEREOF, the parties have executed this Agreement on the
dates set forth below.
LANDLORD TENANT
South Bay/San Xxxxx Associates, Auspex Systems, Inc.,
a California general partnership a Delaware corporation
By: CIIF Associates II Limited
partnership, a Delaware limited By:
partnership, its general partner --------------------------------
Its:
By: AEW Advisors, Inc., -------------------------------
a Massachusetts corporation,
its managing general partner
By:
-------------------------
Its:
------------------------
38-b
45
EXHIBIT "A"
Legal Description of Parcel
39
46
EXHIBIT "B"
Site Plan
40
47
EXHIBIT "C"
Improvement Agreement
THIS IMPROVEMENT AGREEMENT by and between SOUTH BAY/SAN XXXXX
ASSOCIATES ("Landlord") and AUSPEX SYSTEMS, INC. ("Tenant"), dated January ,
1997, is made part of that Lease (the "Lease"), between Landlord and Tenant,
dated concurrently herewith. Landlord and Tenant agree that the following terms
are part of the lease:
1. Definitions: Except as defined below, capitalized terms in this
Improvement Agreement shall have the meanings given those terms in the Lease.
(a) Architect shall collectively mean all architects,
structural engineers, mechanical engineers, and other design professionals
retained by Landlord and needed to design the Tenant Improvements.
(b) Applicable Laws and Restrictions shall mean all laws
(including without limitation the Americans With Disabilities Act), building
codes, ordinances, regulations, title covenants, conditions and restrictions.
(c) Approved Plans shall mean the Final Tenant Improvement
Plans, as the same may be modified by a Change Order issued in accordance with
this Improvement Agreement.
(d) Building shall mean each Building Shell and the Tenant
Improvements therein.
(e) Buildings shall mean all of the Building Shells and all of
the Tenant Improvements.
(f) Building Shell shall mean each (concrete or two story
tilt-up R&D building), having the general specifications described on attached
Exhibit 1, which shall be constructed by Landlord for Tenant generally in the
location and configuration shown on Exhibit B to the Lease.
(g) Construction Documents shall mean the Final Tenant
Improvement Plans, and any and all bid packages, contracts with Contractors and
agreement with the Architect.
(h) Contractor(s) shall mean South Bay Construction and
Development Company and all other contractors, design-build contractors,
subcontractors, and material supplies who provide labor and material for
construction of the Tenant Improvements. To the extent required by Applicable
Laws and Restrictions, each Contractor shall be duly licensed by the State of
California.
41
48
(i) Construction Schedule shall mean the schedule for the
commencement, prosecution and Substantial Completion of the Tenant Improvements,
which shall be in substantially the form of attached Exhibit 2, and which shall
be approved by the parties pursuant to this Improvement Agreement and, when
agreed upon attached hereto in replacement of Exhibit 2 and incorporated herein
by this reference.
(j) Final Tenant Improvement Plans shall mean those plans,
specifications and working drawings for the Tenant Improvements, which shall be
prepared, approved and identified in Exhibit 3 when approved in writing by
Landlord and Tenant, and thereafter incorporated herein by this reference.
(k) Force Majeure shall mean any prevention, delay or stoppage
due to strikes, lock-outs, inclement weather, labor disputes, inability to
obtain labor, materials, fuels or reasonable substitutes therefor, governmental
restrictions, regulations, controls, action or inaction, civil commotion, fire
or other acts of God, and other causes beyond the reasonable control of the
party obligated to perform (except financial inability) shall excuse the
performance, for a period equal to the period of any said prevention, delay or
stoppage, or any obligation hereunder except the obligation of Tenant to pay any
sums due hereunder.
(l) Landlord's Representative shall mean Xxxxx Xxxxxx, whose
telephone number is (000) 000-0000, whose facsimile number is (000) 000-0000,
and whose address for delivered notice is South Bay Development Company, Inc.,
000 Xxxxxxxx Xxxxxx, Xxxxxxxx, Xxxxxxxxxx 00000, or such other person as
Landlord shall designate in writing to Tenant as its authorized representative
for the proposes of administering this Improvement Agreement. Landlord's
Representative may change its numbers and address by deliver of three (3)
business days notice to Tenant's Representative.
(m) Planning Schedule shall mean the schedule for the
preparation, approval and permitting of the Approved Plans for the Tenant
Improvements attached hereto as Exhibit 4, and incorporated herein by this
reference.
(n) Permits shall mean all of the permits, inspections,
approvals and consents of governmental authorities.
(o) Substantial Completion shall mean that (i) the Tenant
Improvements have been completed in accordance with the provisions of this
Improvement Agreement and the Final Tenant Improvement Plans therefor (except
for minor punchlist items which do not substantially interfere with Tenant's use
of the Premises), (ii) all utilities are connected and available for Tenant's
use, and (iii) all necessary governmental approvals for occupancy of the
Buildings have been obtained (including, if applicable, a certificate of
occupancy); provided, however that, to the extent that Substantial Completion of
the Buildings is delayed because of a Tenant Delay, the Substantial Completion
Date shall be deemed to be the date the Buildings would have otherwise been
Substantially Completed, absent the Tenant Delay.
42
49
(p) Tenant Delay shall mean any delay in the Substantial
Completion of the Tenant Improvements as a consequence of (i) Tenant's failure
to promptly review and approve or properly disapprove plans for the Tenant
Improvements in accordance with this Improvement Agreement and within the time
permitted by the Planning Schedule; (ii) Tenant's request for special materials,
finishes, or installations which are not readily available, provided the length
of Tenant Delay due to such unavailability shall not exceed the amount of delay
approved by Tenant when such materials, components, finish, or improvements were
requested by Tenant; (iii) Change Orders requested by Tenant and approved by
Landlord, provided that the amount of Tenant Delay as a consequence of any
Change Order may not exceed the amount of delay specified in the Change Order;
(iv) Tenant's failure to complete any of its own improvement work identified in
the Construction Schedule as being necessary for the Substantial Completion of
the Tenant Improvements by the date specified in the Construction Schedule for
completion of such work; (v) interference with Landlord's work caused by Tenant
or Tenant's contractors or subcontractors.
(q) Tenant Improvements shall mean those improvements that
Landlord is obligated to construct in the Premises pursuant to Final Tenant
Improvement Plans.
(r) TI Allowance shall mean an amount equal to Four Million
Two Hundred Eighty Four Thousand Five Hundred Fifty Dollars ($4,284,550), which
allowance is already reflected in the Monthly Installment amount set forth in
Subparagraph 4.B. of the Lease.
(s) TI Costs shall mean all sums (i) paid to Contractors for
labor and materials furnished in connection with construction of the Tenant
Improvements; (ii) all costs, expenses, payments, fees, and charges whatsoever
paid or incurred by Landlord to or at the direction of any city, county, or
other governmental authority or agency which are required to be paid by Landlord
in order to obtain all necessary governmental permits, licenses, inspections and
approvals relating to the construction of the Tenant Improvements and the use
and occupancy of the Premises, including without limitation all in lieu fees and
utility fees; (iii) engineering and architectural fees for services required in
connection with the design and construction of the Tenant Improvements; and (iv)
premiums, if any, for course of construction insurance and for payment and
completion bonds relating only to construction of the Tenant Improvements. In no
event shall TI Costs include any of the following, all of which shall be the
sole obligation of Landlord: (a) any cost attributable to the Building Shell,
including without limitation the cost to design, permit, or construct the
Building Shell improvements described on Exhibit 1 to this Exhibit "C", (b)
charges and expenses for changes to the Construction Documents which have not
been approved in writing by Tenant, except for those changes to the Construction
Documents required by governmental authority, (c) wages, labor and overhead for
overtime and premium time, unless approved in writing by Tenant; (d) additional
costs and expenses incurred by Landlord on account of any Contractors' or
Architects' default or construction defects in the Improvements; (e) interest
and fees for construction financing; (f) labor and overhead costs for Landlord's
employees and office; and (g) bond premiums.
(t) TI Cost Estimate shall mean the total estimated cost of
constructing the
43
50
Tenant Improvements prepared and approved by Landlord and Tenant in accordance
with this Improvement Agreement, as modified by change orders issued in
accordance with this Improvement Agreement.
2. Designation of Representative. Landlord and Tenant hereby
respectively appoint Landlord's Representative and Tenant's Representative as
its sole representative for the purposes of this Improvement Agreement. Until
replaced by written notice, Landlord's Representative and Tenant's
Representative shall have the full authority and responsibility to act on behalf
of Landlord and Tenant, respectively, as required in this Improvement Agreement.
3. Preparation and Approval of Plans.
(a) Retention of Architect(s). Tenant shall retain the
Architect(s) to prepare the plans and specifications for the Tenant
Improvements, subject to Landlord's reasonable approval.
(b) Tenant Improvement Plans.
(i) To facilitate timely commencement and Substantial
Completion of the Tenant Improvements, within the time specified in the Planning
Schedule, Tenant shall prepare and submit to Landlord for Landlord's approval
the Tenant's design requirements for the Tenant Improvements. At such time as
Landlord has approved the Tenant's design requirements and within the time
provided in the Planning Schedule, Landlord shall cause the Architect to proceed
with the preparation of preliminary plans and specifications, and a preliminary
cost estimate for the Tenant Improvements and shall notify Tenant of any
revisions that may need to be made to the previously approved construction
schedule. Tenant shall review and approve or disapprove of such items and any
changes in the Construction Schedule within the time permitted by the Planning
Schedule. If Tenant does not approve any preliminary plan or specification, the
preliminary cost estimate, or a construction schedule change, Tenant and
Landlord shall work with the Architect and negotiate in good faith to reach
agreement on all such items within the time permitted by the Planning Schedule.
(ii) When the preliminary space plans, elevations,
preliminary cost estimate and any Construction Schedule changes have been
approved by Tenant, Landlord shall cause the Architect to prepare and deliver to
Tenant by the date specified in the Planning Schedule (i) proposed final plans,
specifications and working drawings for the Tenant Improvements, (ii) a proposed
final TI Cost Estimate, and (iii) a proposed final Construction Schedule for the
Improvements substantially in the form of attached Exhibit 2, all of which shall
be consistent with, and logical evolutions of the preliminary plans and
elevations approved by Tenant pursuant to the foregoing, the terms of this
Improvement Agreement and the Construction Schedule and the changes thereto
previously approved by the parties. Tenant shall review and approve the proposed
final plans, specifications, and working drawings for the Tenant Improvements,
the proposed TI Cost Estimate, or the proposed final Construction Schedule
within the time permitted by the Planning Schedule. If Tenant reasonably
disapproves of the
44
51
plans, specifications or working drawings for the Tenant Improvements (which
disapproval can only be based upon whether such plans, specification or working
drawings are consistent with the preliminary plans), the proposed TI Cost
Estimate, and/or the proposed final Construction Schedule, then Landlord and
Tenant shall negotiate in good faith, using all reasonable efforts to reach
agreement on such items within the time specified in the Planning Schedule;
provided, however, that Landlord shall not unreasonably withhold its approval of
such change requested by Tenant to the Tenant Improvements which does not
materially delay the Scheduled Completion Date for the Tenant Improvements nor
materially increase the cost that will be incurred by Landlord in constructing
the Tenant Improvements. If Tenant believes that the cost estimate is incorrect,
it may require that all or any portion of the work be submitted for competitive
bids, in which case the amount for the rebid work included in the TI Cost
Estimate shall not exceed the lowest responsible bid(s) from responsible
Contractor(s) and Supplier(s) for such work. The plans, specifications, and
working drawings for the Tenant Improvements, the final TI Cost Estimate, and
the Construction Schedule approved by Tenant and Landlord pursuant to this
Section, shall be the "Final Tenant Improvement Plans," "TI Cost Estimate" and
"Construction Schedule" for the purposes of this Improvement Agreement.
(c) Disapprovals and Failures to Respond. Any disapproval by
Tenant of a preliminary plan, space plan, elevation final plan, specification,
cost estimate, or construction schedule item submitted for its approval shall be
communicated only by a writing, which is delivered to Landlord within the time
permitted by the Planning Schedule and which specifies the disapproved item(s),
the reason(s) for the disapproval, and the changes required to make the item
acceptable to Tenant. If Tenant's disapproval of any item requiring its approval
under this Construction Agreement is not delivered in accordance with the
procedures and time limits specified in this Improvement Agreement, then Tenant
shall be deemed to have given its approval to such item.
(d) Changes to Plans, Cost Estimate and Construction Schedule.
When the Final Tenant Improvement Plans, the TI Cost Estimate and Construction
Schedule have been approved by Landlord and Tenant as provided above, the
description of said plans and the Construction Schedule shall be initialed by
the parties and attached to this Agreement as Exhibits 2 and 3, respectively.
Once the Final Tenant Improvement Plans, the TI Cost Estimate, and the
Construction Schedule (including, without limitation, the Scheduled Completion
Date specified therein) are approved by Landlord and Tenant as provided above,
neither party shall thereafter have the right to order extra work or change
orders, nor will the Construction Schedule or the TI Cost Estimate be modified,
except by a written "Change Order" approved by Landlord and Tenant, which
approval shall not be unreasonably withheld, except as expressly stated to the
contrary below. The Change Order shall clearly describe (i) the change, (ii) the
party required to perform the change, (iii) any modification of the Approved
Plans, (iv) the amount of delay or the time saved resulting therefrom and any
revision of the Construction Schedule and Scheduled Completion Date occasioned
by the change, (v) any added or reduced TI Cost resulting from the Change, (vi)
any other cost, and the manner of payment of such costs which Tenant may be
required to pay with respect to a Change requested by Tenant, or Landlord may be
required to reimburse to Tenant as a consequence of a change requested by
Landlord.
45
52
(e) Application for Permits. As soon as the Final Tenant
Improvement Plans are approved by Landlord and Tenant, Landlord shall submit
said plans to all appropriate governmental agencies and private parties from
whom Permits are required for the construction and use of the Tenant
Improvements. Landlord shall notify Tenant of any changes required by any
governmental agencies, and Tenant shall have seven (7) days thereafter to
indicate its approval thereof. All such changes required by governmental
agencies shall be deemed acceptable to Tenant unless Tenant's use of the
Premises is materially impaired thereby. The final plans, specifications and
working drawings as approved, and all change orders specifically permitted
pursuant to Subparagraph (c) below, shall be referred to herein as the "Approved
Plans."
4. Construction.
(a) General Contractor. South Bay Development and Construction
Company shall serve as the general Contractor. Contractor's fee as general
Contractor for the Tenant Improvements shall be calculated as follows and shall
be included in the TI Cost Estimate: five percent (5%) of the TI Costs not
including such Contractor's fee.
(b) Subcontracts and Materials. Prior to issuance of any
subcontract relating to Tenant Improvements, Landlord shall submit for Tenant's
approval (which approval shall not be unreasonably withheld) a list of the
Contractors and Suppliers for the Tenant Improvement work. At Tenant's request,
all labor and materials for the Tenant Improvements shall be competitively bid
by at least two (2) Contractors or Suppliers. Landlord may also bid on such
work. If Tenant so desires, Tenant may also select a Contractor or Supplier,
reasonably acceptable to Landlord, to bid the work. All bids shall be opened
simultaneously. Landlord shall have the right to select the Contractor or
Supplier to perform the work. Notwithstanding Tenant's right to approve the
Contractors and Suppliers, the Contractors and Suppliers are a contractor only
for Landlord, and Tenant shall have no liability to any Contractor or Supplier
under any Construction Document or otherwise with respect to the Tenant
Improvements; provided, Tenant shall be required to reimburse Landlord for its
portion of the TI Costs pursuant to this Improvement Agreement.
(c) Commencement and Completion of Improvements. As soon as
(i) the Approved Plans have been developed as provided above, and (ii) all
necessary Permits for commencement of construction of the Tenant Improvements
have been obtained, Landlord shall cause its Contractor(s) to commence and to
thereafter diligently prosecute to completion the construction of the Tenant
Improvements in accordance with the Approved Plans by the Scheduled Completion
Dates therefor contained in the Construction Schedule; provided, however,
Landlord shall not be liable for delay in the Substantial Completion Date for
any Building to the extent reasonably attributable to a Force Majeure Delay,
except as specifically provided in this Lease.
(d) Standard of Construction. Landlord shall cause all work to
be constructed
46
53
in a good and workmanlike manner, free from material design and workmanship
defects in accordance with the Approved Plans, the other Construction Documents,
the Permits, and Applicable Law and Restrictions. Notwithstanding anything to
the contrary in the Lease or this Improvement Agreement, Tenant's acceptance of
the Landlord's Work shall not waive the foregoing warranty and Landlord shall
promptly remedy all violations of the warranty at its sole cost and expense
which occur during the first twelve (12) months of the Lease Term. Such warranty
shall expire and be of no further force or effect on the date which is twelve
(12) months after the Commencement Date. Tenant shall promptly notify Landlord
in writing during the warranty period of any defect in construction or in the
operation of equipment discovered during such period, and promptly thereafter
Landlord shall commence the cure of such defect and complete such cure with
diligence at Landlord's sole cost. After said twelve (12) month period, Tenant
shall conclusively be deemed to have approved the construction of the Tenant
Improvements and accepted them "as is", subject only to defects claimed as
provided above. With respect to defects discovered after the expiration of said
one (1) year period, the parties hereto acknowledge that it is their intention
that Tenant have the benefit of any construction or equipment warranties
existing in favor of Landlord that would assist Tenant in correcting such
construction defects and in discharging its obligations regarding the repair and
maintenance of the Premises. Upon request by Tenant following the expiration of
such twelve (12) month period, Landlord shall inform Tenant of all written
construction and equipment warranties existing in favor of Landlord which affect
the Tenant Improvements. Landlord shall assign such warranties to Tenant upon
request in order that Tenant may enforce the same.
(e) Tenant Fixturing. Landlord shall use all reasonable
efforts to complete construction of Tenant Improvements of each Building to a
point permitting Tenant's entry for installation of its fixtures and equipment
on or before the date specified in the Construction Schedule. When the
construction of each Building has proceeded to the point where Tenant's
installation of its fixtures and equipment in the Building can be commenced in
accordance with good construction practice, the Landlord shall notify Tenant to
that effect and shall permit Tenant and its authorized representatives and
contractors to have access to the Building for a period of not less than thirty
(30) days for the purpose of installing Tenant's trade fixtures, equipment and
other Tenant's Property in the Building. Landlord and Tenant shall cooperate in
good faith to schedule and coordinate Tenant's fixturing with the Landlord's
construction in a manner which will assure Substantial Completion of the
Improvements by the Scheduled Completion Dates, will reduce each party's cost,
and ensure labor harmony. While performing fixturing, Tenant shall comply, and
shall cause its employees, contractors and suppliers to comply, with the
reasonable work rules observed by Landlord's Contractors and Suppliers.
(f) Inspection & Punchlist. Tenant's Representative and
Tenant's architect, designers and consultants shall have the right to enter on
the Premises at all reasonable times and upon notice to Landlord's
Representative for the purpose of inspecting the progress of the work. Tenant's
Representative, Landlord's Representative and the Architect(s), and such
advisers as they shall desire, shall inspect each Building upon its Substantial
Completion using their best efforts to discover all uncompleted or defective
construction. After such inspection has been completed, a list of "punchlist"
items shall be prepared by Landlord which the parties agree are to
47
54
be corrected by Landlord. Landlord shall use its best efforts to complete and/or
repair such "punchlist" items within thirty (30) days. Tenant's taking
possession of the Premises shall be deemed to be an acceptance by Tenant of the
Premises as complete and in accordance with the terms of this Lease, subject to
completion of the punchlist items within said period.
5. Payment of Construction Costs. Landlord and Tenant shall each bear
their own cost for performance of their respective obligations under this
Improvement Agreement, except that Tenant shall reimburse Landlord for the
amount, if any, by which the TI Cost exceeds the TI Allowance in the following
manner: Landlord shall submit receipted bills and/or lien releases evidencing
Landlord's payment of TI Costs in such amounts and at such times as bills are
submitted to Landlord for the TI Costs by Contractors and Suppliers for Tenant
Improvement work in place prior to the date of the xxxx (a "TI Progress Cost").
On or before the twenty-fifth (25th) day following receipt of the request,
Tenant shall pay to Landlord a sum equal to (i) the TI Progress Cost times a
fraction, the numerator of which shall be equal to the TI Cost Estimate minus
the TI Allowance and the denominator of which shall be equal to the TI Cost
Estimate, minus (ii) the sums previously reimbursed by Tenant to Landlord;
provided, however that in no event shall Tenant be required to reimburse
Landlord (1) for more than 90% of the difference between the TI Cost Estimate
and the TI Allowance prior to the Substantial Completion Date, (2) so long as
Landlord has failed to use the reimbursements previously paid by Tenant to
discharge the obligation of the Landlord to the Contractors and Suppliers, or
(3) so long as Landlord is in default of its obligations under this Improvement
Agreement in any material respect.
6. Delay In Completion Caused By Tenant. The parties hereto acknowledge
that the date on which Tenant's obligation to pay the Monthly Installment would
otherwise commence could be delayed because of Tenant Delays. It is the intent
of the parties hereto that Tenant's obligation to pay the Monthly Installments
of rent not be delayed by any of such causes or by any other act of Tenant, and
in the event it is so delayed, then Tenant's obligation to pay the Monthly
Installments shall commence as of the date it would otherwise have commenced
absent said Tenant Delay. Tenant Delays in excess of thirty (30) days for any of
the above-mentioned reasons may affect Landlord's financing of construction of
the Premises, and Tenant agrees to pay any reasonable additional financing
costs, including loan fees, incurred by Landlord as a result thereof.
7. Notices. The notices to be delivered to the parties pursuant to this
Improvement Agreement shall be given by personal delivery or by facsimile (with
receipt confirmed) to the Tenant's Representative and the Landlord's
Representative at the following address and facsimile number.
48
55
Tenant's Representative: [FOLLOWING EXECUTION OF THIS LEASE, TENANT
SHALL PROMPTLY PROVIDE LANDLORD WITH THE NAME, ADDRESS AND FACSIMILE
NUMBER FOR TENANT'S REPRESENTATIVE.]
Address:
---------------------------------------------------------------
-----------------------------------------------------------------------
-----------------------------------------------------------------------
-----------------------------------------------------------------------
Facsimile:
-------------------------------------------------------------
Landlord's Representative:
Address: South Bay Development Company, Inc.
000 Xxxxxxxx Xxxxxx
Xxxxxxxx, Xxxxxxxxxx 00000
Attn: Xx. Xxxxx Xxxxxx
Facsimile: (000) 000-0000
8. Miscellaneous. Except as otherwise expressly provided in this
Improvement Agreement, whenever either party's consent, approval, designation,
or advice is required by the other party, such consent, approval, designation,
or advice shall not be unreasonably withheld or delayed. This Improvement
Agreement and the Lease contain the entire agreement between the parties with
respect to the construction of the Tenant Improvements and, in the event of any
conflict between the terms of this Improvement Agreement and the Lease, this
Improvement Agreement shall prevail. This Improvement Agreement may be amended
and the provisions hereof may be waived only by a writing signed by Landlord and
Tenant and the provisions hereof shall be binding upon the successors and
assigns of the parties to the Lease. If any legal action, arbitration or other
proceeding is commenced to interpret or enforce this Improvement Agreement, the
prevailing party in such action, arbitration or proceeding shall be entitled to
recover its reasonable attorneys' fees and costs.
49
56
IN WITNESS WHEREOF, the parties have executed this Agreement on the
dates set forth below.
LANDLORD TENANT
South Bay/San Xxxxx Associates, Auspex Systems, Inc.,
a California general partnership a Delaware corporation
By: CIIF Associates II Limited
partnership, a Delaware limited By:
partnership, its general partner ------------------------------
Its:
By: AEW Advisors, Inc., ------------------------------
a Massachusetts corporation,
its managing general partner
By:
---------------------------
Its:
--------------------------
50
57
EXHIBIT 1 TO EXHIBIT C
DEFINITION OF BUILDING SHELLS
The components and systems below shall be included in the design of the new
buildings. All code requirements should be considered minimum beginning
requirements and not the highest level of design. Landlord's cost shall include
all "hard and soft" costs related to the construction of the site and shell,
including architectural and engineering services, permits, utility fees for
connections and meters, etc.
1. BUILDINGS STRUCTURE
(a) All foundations to include footings, piers, caissons, pilings,
grade beams, foundation walls or other building foundation
components required to support the entire building structure.
(b) Columns shall be steel box or pipe columns.
(c) All columns, beams, joists, purlins, headers, or other framing
members to support the roof and roofing membrane.
(d) Five inch (5") thick concrete slab on grade with welded wire
mesh and any other reinforcing or structural connections that
may be necessary or required.
(e) Exterior walls that enclose the perimeter of the building with
steel reinforcing and structural connections that may be
necessary or required.
(f) All exterior glass and glazing with anodized aluminum frames.
Glass to be tinted as appropriate to the aesthetic design of
the building. All exterior doors, door closer and locking
devices necessary for proper functioning.
(g) Wood panel roof system to support roofing membrane.
(h) Three (3) ply built up roofing with cap sheet and all
flashings by Xxxxx-Xxxxxxx, Xxxx Xxxxxxxx, or equal.
(i) Exterior painting of all concrete with Tex-Coat or Kel-Tex
textural paint. All caulking of exterior concrete joints in
preparation for painting.
(j) The multi-story buildings are to be designed for a minimum of
one
51
58
elevator per building, the elevator shafts to be a part of
Landlord's shell costs.
(k) The foundation and structural framing should be designed to
support a minimum live load of 100 psf in all areas.
(l) The floor-to-floor height of the buildings shall allow a
minimum of 10'- 0" interior drop ceiling height.
2. PLUMBING
(a) Underground sanitary sewer laterals connected to the city
sewer main in the street and piped into each building and
under the concrete slab on grade for the length of the
buildings. Main waste lines under the slabs will be in as
close proximity as possible to the building rest room
locations.
(b) Domestic water mains connected to the city water main in the
street and stubbed to the buildings. Water mains to each
building shall not be less than 2.5" in size.
(c) Roof drain leaders piped and connected to the site storm
drainage systems.
(d) Gas lines connected to the city public utility mains and gas
meters adjacent to, and in close proximity to each building.
Meters supplied by utility company.
3. ELECTRICAL
(a) All primary electrical service to each building that is
complete including underground conduit and wire feeders from
transformer pads into the building's main switchgear
electrical room. The electrical characteristics of the
secondary side of transformers shall be 277/480 Volt. 3 Phase
and the rated capacity of the transformers shall be 2,000 amps
for each building. All electrical panels and breakers will
have isolated grounds and surge protectors.
(b) Underground pull section, meter, and panel(s), for site
lighting and landscaping.
(c) Underground conduit from the street to the building for
telephone trunk line service by Pacific Telephone. Conduit to
each building shall not be less than 4".
52
59
(d) An electrically operated landscape irrigation controller that
is a complete and functioning system.
(e) Underground conduit from the building to the main fire
protection system, shut off valve (PIV) for installation of
security alarm wiring.
(f) All parking lot and landscaping lighting to include fixtures,
underground conduit, wire, distribution panel and controller.
All exterior lighting shall be a complete and functioning
system.
4. FIRE PROTECTION (SPRINKLERS)
(a) A complete and fully functional overhead system distributed
throughout the building. The systems shall be classified
ordinary hazard group II and be distributed throughout the
building.
(b) System shall include all sprinkler heads that may be required
by building codes above the ceiling, when ceilings are
installed.
(c) Site sprinkler main to be sized adequately to support Tenant's
uses within each building.
5. SITEWORK
(a) All work outside the building perimeter walls shall be
considered site work for the building shell and shall include
grading, asphalt concrete, paving, landscaping (hard and
soft), landscape irrigation, storm drainage, utility service
laterals, including conduit for voice and data connecting the
buildings, curbs, gutters, sidewalks, specialty paving (if
required), retaining walls, fencing and gates, trash
enclosures, planters, sign monuments, parking lot and
landscape lighting and other exterior lighting per code.
(b) Paving sections for automobile and truck access shall be
according to the Geological Soils Report.
(c) All parking lot striping to include handicap signage and
spaces (parking ratio: no less than 1 space per 295 gross
square feet).
(d) Underground site storm drainage system shall be connected to
the city storm system main.
53
60
EXHIBIT 2 TO EXHIBIT C
CONSTRUCTION SCHEDULE
[TO BE DETERMINED]
54
61
EXHIBIT 3 TO EXHIBIT C
FINAL TENANT IMPROVEMENT PLANS
[TO BE DETERMINED]
55
62
EXHIBIT 4 TO EXHIBIT C
PLANNING SCHEDULE
[TO BE DETERMINED]
Required Action Last Date for Completion
---------------------------------------------------------------------------------------------------------
Tenant Improvements Plans and Specifications
---------------------------------------------------------------------------------------------------------
1. Tenant delivers its design , 199
----------------------------
requirements to .
----------------------------
2. Landlord causes the Architect to days after Task 1 is satisfied
--------------
deliver preliminary plans, and a preliminary cost
estimate for the Tenant Improvements and a list of any
expected construction schedule changes to Tenant for
its review.
3. Tenant approves or disapproves the days after Task 2 is completed
--------------
items delivered pursuant to Task 8.
4. Landlord and Tenant agree upon , 199
----------------------------
preliminary plans, a cost estimate and any construction
schedule changes for Tenant Improvements.
5. Landlord delivers proposed plans, days after Task 4 is completed
--------------
specifications and working drawings, a proposed final TI Cost Estimate for the
Tenant Improvements, and a final Construction Schedule to Tenant for its review.
6. Tenant approves or disapproves the days after Task 5 is completed
--------------
items delivered pursuant to Task 1.
7. Landlord and Tenant agree upon , 199
----------------------------
Final Tenant Improvement Plans, a final TI Cost Estimate, and a final
Construction Schedule.
Permitting & Governmental Approvals
---------------------------------------------------------------------------------------------------------
8. Landlord submits the Final Tenant days after Task 7 is completed
--------------
Improvement Plans to all applicable governmental
authorities for Permits.
9. All governmental permits and , 199
---------------------------
approvals necessary for the construction of the
Improvements for the Permitted Uses are obtained.
56
63
EXHIBIT "D"
Commencement Date Memorandum
With respect to that certain Lease Agreement ("Lease"), dated January
____, 1997, by and between South Bay/San Xxxxx Associates, a California general
partnership ("LANDLORD"), and Auspex Systems, Inc., a Delaware corporation
("TENANT"), whereby Landlord leased to Tenant and Tenant leased from Landlord
the Premises (as defined in the Lease). All terms not defined herein shall have
the same meaning as set forth for such terms in the Lease. Tenant hereby
acknowledges and certifies to Landlord as follows:
(1) The Lease commenced on ___________________, 19___ ("Commencement
Date");
(2) The Initial Term of the Lease shall expire on ____________________,
______ (the "Expiration Date");
(3) The initial Monthly Installment of Rent for the Premises is
____________ _______________________________ Dollars ($_________________); and
(4) Tenant has accepted [and is currently in possession of] the
Premises.
IN WITNESS WHEREOF, this Commencement Date Memorandum is executed this
______ day of __________________, 199____.
"Tenant"
Auspex Systems, Inc., a
Delaware corporation
By:
-------------------------------
Its:
------------------------------
57
64
EXHIBIT "E"
List of Hazardous Materials
Tenant Will Use on The Premises
58
65
EXHIBIT "F"
Description of Existing Environmental Reports
Environmental Reports & Correspondence
The Former Unisys Site
1. Environmental Baseline Report - Revised October 1989
A. Including the following tables, figures and appendices (359 pages)
Tables
1. Tanks and Chemical Storage
2. Previous Tank Storage Summary
3. Groundwater Monitoring Data 10/88
Figures
1. Map
2. Site Map
3. Tank Locations
4. Previous Tank Storage Sites
5. Monitoring Well Locations
Appendices
PCB Information
Asbestos Information
Tank Pull 1/84
Well Destruction Investigation
Hydrogeological Investigation 10/87
Unisys for SFRWQCB; Environmental Baseline
Investigation (Appx 60 pages)
Hydrogeological Investigation 11/88
Soil Gas Survey 5/89
Semi-Annual Sampling 5/89
Clarifier Removal 10/89
59
66
2. Tank Removal - Completed 2/6/90 - Santa Xxxxx Fire Department Permit
3. Internal Memo 3/2/90 Regional Water Quality Control Board/2 pages
4. Letter: 3/5/90 to Unisys from Pacific Environmental Group, Inc./4 pages
5. Table 1: Summary of Current Groundwater Laboratory Results/4 pages.
6. Letter: 6/11/90 to E2C, Inc. from Chips Environmental Consultants/16
pages
7. Letter: 6/28/90 to South Bay Construction and Development Company from
E2C, Inc./3 pages
8. Report: 6/29/90 Level II Environmental Site Assessment prepared by E2C,
Inc. previously forwarded to ASK 3/17/92
9. Television inspection location sheet dated 7/16/90-VCR tape available/2
pages
10. Letter: 7/19/90 to City of Santa Xxxxx from E2C, Inc./1 page
11. Progress report sanitary sewer line video and groundwater analysis
dated 8/7/90 prepared by E2C, Inc./44 pages
12. Letter: 8/31/90 to South Bay Construction and Development Company from
E2C, Inc./3 pages
13. Television inspection location sheet dated 8/31/90-VCR tape available/2
pages
14. Letter: 10/19/90 to Prevention Bureau, Santa xxxxx Fire Department from
Pacific Environmental Group, Inc./22 pages
15. Letter; 10/23/90 to South Bay Construction and Development Company from
Unisys/9 pages
16. Letter: 11/1/90 to South Bay Construction and Development Company from
Unisys/9 pages
17. Letter: 11/1/90 to Prevention Bureau, Santa Xxxxx Fire Department from
Pacific Environmental Group, Inc./8 pages
18. Letter: 11/21/90 to South Bay Construction and Development Company from
E2C, Inc./6 pages
19. Letter: 1/3/91 to South Bay/San Xxxxxx Associates from Unisys/2 pages
20. Memo: 1/29 91 to Xxxxxx Xxxxxxxxxxx from Pacific Environmental group,
Inc./41 pages
21. Fax: 2/11/91 to Unisys from E2C, Inc./7 pages
22. Final submittals-Xxxxxx Xxxxxxxxxxx-Asbestos/25 pages
23. Letter: 3/15/91 to Pacific Environmental Group from Xxxxxxx
Environmental Consultants/26 pages
24. Letter: 3/19/91 to E2C, Inc., from Pacific Environmental Group, Inc./16
pages
25. Letter: 3/21/91 to South Bay/San Xxxxx Associates from Unisys/16 pages
60
67
26. Letter: 3/21/91 to Unisys from Pacific Environmental Group, Inc./12
pages
27. Letter: 3/22/91 to South Bay Development Company from Unisys/2 pages
28. Fax: 4/4/91 to Pacific Environmental Group/1 page
29. Fax: 4/4/91 to Pacific Environmental Group/1 page
30. Fax: 4/8/91 from Pacific Environmental Group-Organic Analysis Data
Sheets/8 pages
31. Fax: 4/10/91 from Pacific Environmental Group-Permits Santa Xxxxx Fire
Department/5 pages
32. Letter: 4/12/91 to San Francisco Regional Water Quality Control Board
from Unisys/81 pages
33. Letter: 4/23/91 to South Bay Development Company from Unisys/1 page
34. Letter: 5/21/91 to South Bay Development Company from Unisys/7 pages
35. Uniform Hazardous Waste Manifests 5/22/91/44 pages
36. Letter: 6/5/91 to Unisys from California Regional Water Quality Control
Board/2 pages
37. Report of Abatement Observation and Air Monitoring June 6, 1991
prepared by Law Associates/66 pages
38. Letter. 6/20/91 to Unisys from Pacific Environmental Group, Inc./18
pages
39. Soil & Groundwater Assessment dated July 11, 1991, prepared by E2C,
Inc.
40. Fax: 8/28/91 to SBC&D Co., from E2C, Inc./7 pages
41. Letter: 1/14/92 to California Regional Water Quality Control Board from
Unisys/8 pages
42. Letter: 1/14/92 to Unisys from Pacific Environmental Group, Inc./4
pages
43. Report: 1/20/92 Second and Third Quarter Split Sampling prepared by
E2C, Inc./121 pages
44. Letter: 2/3/92 from Unisys from California Regional Water Quality
Control Board/2 pages
45. Letter: 3/24/92 to South Bay Construction and Development from E2C,
Inc./8 pages
46. Letter: 3/25/92 to Regional Water Quality Control Board from Unisys/12
pages
47. Report: 4/2/92 Installation of B-Zone Well prepared by E2C, Inc./53
pages
48. Report: 8/25/92 Phase I Environmental Assessments Building 14 prepared
for the ASK Companies by Environ Corporation
49. Letter: 11/10/92 to South Bay Development Company from Unisys/9 pages;
Justification for Removal
50. Letter: 12/11/92 to South Bay Construction and Development company from
E2C, Inc./3 pages
61
68
51. Letter 12/11/92 to South Bay Construction and Development Company from
E2C, Inc./4 pages
52. Letter: 12/11/92 to Regional Water Quality Control Board from Unisys/8
pages; Table-Unisys Monitoring Well Removal Notification
53. Letter: 12/14/92 to Regional Water Quality Control Board from E2C,
Inc./4 pages
54. Letter: 12/21/92 to E2C, Inc. from California Regional Water Quality
Control Board/1 page
55. Letter: 12/28/92 to The ASK Companies from South Bay Construction and
Development Company/1 page
56. Letter: 1/22/93 to Regional Water Quality Control Board from Unisys/1
page
57. Fax: 3/29/93 to South Bay Construction and Development Company from
E2C, Inc./2 pages
58. Letter: 4/1/93 to South Bay/San Xxxxx from E2C, Inc./1 page
59. Letter: 4/8/93 to South Bay Construction and Development Company from
E2C, Inc./8 pages; Well Destruction Report
60. Letter: 6/15/93 to Regional Water Quality Control Board from Unisys/15
pages; Well Abandonment Report
61. Site Investigation Summary by Unisys Corporate Environmental Affairs
dated March 6, 1995 containing Report, Figures, Tables and Appendices A
through D
62. Letter: 6/22/95 to Regional Water Quality Control Board from Unisys/21
pages
63. Letter: 9/11/95 to Regional Water Quality Control Board from Unisys/8
pages
64. Letter: 12/19/95 to South Bay Construction and Development Company from
Unisys/14 pages
65. Letter: 1/26/96 to California Regional Water Quality Control Board from
Unisys/21 pages
66. Fax: 4/10/96 to Xxxxx Xxxxxxxxx from Asbestos Control Center/13 pages
67. Report: 7/19/96 System Installation and Additional Investigation
prepared by Unisys Corporate Environmental Affairs
62
69
EXHIBIT "G"
Preliminary Title Report
63
70
EXHIBIT "H"
CC&R's and Excluded Obligations
Under CC&R's Described in the Title Report
The documents referred to in the following specially enumerated
exceptions in the Title Report attached as Exhibit "G" to this Lease constitute
the "CC&R's" referred to in Paragraph 34 of the Lease. Pursuant to Paragraph 34
of the Lease, except as otherwise stated below as being obligations of Landlord,
Tenant shall abide by and comply during the Lease Term with the obligations
stated below with respect to the documents listed below to the extent the
obligations arise from the ownership or occupancy of the Premises (and to the
extent they arise from Landlord's ownership of the Premises together with
Landlord's ownership of other property, then to the extent such obligations are
reasonably allocable to the Premises).
Exception No. 4 pertains to an Agreement Regarding Separation of
Certain Utilities between the City of Santa Xxxxx and Xxxxxx Xxxxxxxxxxx. Tenant
shall not be responsible for any obligations thereunder, with any obligations
affecting the Premises to be borne by Landlord.
Exception No. 5 pertains to a Grant Deed with Grant and Reservation of
Easements from Xxxxxx Xxxxxxxxxxx to Landlord. Tenant shall be responsible for
the obligations embodied therein as relate to the use by Tenant of the easements
which are reflected therein as appurtenances to the Premises.
Exception No. 7 pertains to a Declaration of Covenants, Conditions,
Restrictions and Easements between Landlord and Xxxxxx Xxxxxxxxxxx. Tenant shall
be responsible for the obligations thereunder pertaining to maintaining ingress
and egress easement areas located within the boundaries of the Premises in the
manner required by that Declaration and for the obligations not to unreasonably
interfere with the surface water drainage easement in favor of Unisys over the
Premises.
Exception No. 5 pertains to a Grant Deed with Reservation of Easement
from Xxxxxx Xxxxxxxxxxx to Landlord, which grants Xxxxxx Xxxxxxxxxxx certain
rights of access over the Premises associated with the operation of groundwater
monitoring xxxxx on the Property. Paragraph 2(b) of this document indicates that
the rights and obligations of the parties thereunder are set forth in and are
subject to certain terms and conditions in the Agreement of Purchase and Sale
and Escrow Instructions between Landlord and Xxxxxx Xxxxxxxxxxx. Tenant's only
obligation with regard to the easements reserved in this Grant Deed is not to
unreasonably interfere with the access of Unisys to any monitoring xxxxx that
may be hereafter placed upon the Property. Landlord shall be responsible under
this Lease to ensure that if any monitoring xxxxx are to be installed on the
Premises by Unisys, that they shall be installed in a manner which will not
unreasonably interfere with Tenant's use of the Premises and that Unisys
exercises its rights under this Grant Deed in manner not to unreasonably
interfere with Tenant's use of the Premises.
Exception No. 9 pertains to a Declaration of Covenants, Conditions,
Restrictions and Easements executed by Landlord. Tenant shall have the
obligations for maintenance of such easements and utilities as are located
within the boundaries of the Premises as referred to in this Declaration, and
the obligation to contribute the share of expenses (as provided therein) which
is allocable to the Premises associated with the costs of maintenance of the
easement areas on other parcels for the benefit of the Premises. As relates to
easements over, under or across the Premises for the benefit of other parcels,
Tenant shall have the right to obtain reimbursement from the owners of other
parcels for the cost of maintenance of the easements in accordance with the
terms of this Declaration, including recovery from Landlord to the extent it is
at such time the owner of any other parcel which is obligated to share in such
costs under this Declaration. Landlord shall cooperate with Tenant in any
collection efforts from other owners.
64
