Exhibit 99
Execution Copy
xxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxxx
Xxxx Xxx Xxxxxxxxxx Xxxx Economic Development Project Area
Redevelopment Agreement
By And Between
The Village of Xxxxxx,
Will County, Illinois
and
CenterPoint Intermodal LLC and CenterPoint Realty
Services, Inc.
Dated as of August 1, 2000
================================================================================
TABLE OF CONTENTS
RECITALS ..............................................................................1
A. Constitutional Authority.......................................1
B. Statutory Authority............................................1
C. Village Board Authority........................................1
D. The Project....................................................1
E. Economic Development Plan......................................2
F. Escrow Agreement...............................................2
G. Village Financing..............................................2
SECTION 1. RECITALS................................................................3
SECTION 2. DEFINITIONS.............................................................3
SECTION 3. THE PROJECT.............................................................9
3.01 The Project....................................................9
3.02 Project Budget................................................10
3.03 Phase I Commitments/Charitable Contributions..................10
3.04 Concept Plan..................................................12
3.05 Construction of TIF Funded Improvements.......................12
3.06 Progress Reports and Survey Updates...........................12
3.07 Special Service Area..........................................12
SECTION 4. FINANCING..............................................................12
4.01 Total Project Costs and Sources of Funds......................12
4.02 TIF Note(s)...................................................12
4.03 Cost Overruns.................................................15
4.04 Base Projected Increment; Updated Projections;
Allocation of Incremental Taxes...............................15
4.05 Village Administrative Costs; Use of Incremental Taxes
by Village and Taxing Districts...............................15
4.06 Use of P.O.S. Sales Tax.......................................16
4.07 Pledge Agreement..............................................16
4.08 Purchase of Section 15D Bonds.................................16
SECTION 5. CONDITIONS PRECEDENT...................................................17
5.01 Other Governmental Approvals..................................17
5.02 [Intentionally Omitted].......................................17
5.03 Insurance.....................................................17
5.04 Legal Opinions................................................17
5.05 SEC Filings...................................................17
5.06 Corporate Documents...........................................17
5.07 Preconditions of Disbursement.................................18
SECTION 6. AGREEMENTS WITH CONTRACTORS............................................18
6.01 General Contractor and Subcontractors.........................18
SECTION 7. COMPLETION OF CONSTRUCTION.............................................18
7.01 Certificate of Completion of Construction.....................18
7.02 Effect of Issuance of Certificate; Continuing Obligations.....18
7.03 Notice of Expiration of Term of Agreement.....................19
SECTION 8. COVENANTS/REPRESENTATIONS/WARRANTIES
OF THE DEVELOPER ......................................................19
8.01 General.......................................................19
8.02 Economic Development Plan.....................................19
8.03 Employment Opportunity........................................20
8.04 Prevailing Wage...............................................20
8.05 Developer's Liabilities.......................................20
8.06 Compliance with Laws..........................................20
8.07 Compliance with Agreements....................................20
8.08 Survival of Covenants.........................................20
SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF VILLAGE........................20
9.01 General Covenants.............................................20
9.02 Survival of Covenants.........................................20
9.03 Nonimpairment.................................................21
9.04 Subordination.................................................21
9.05 Future Revenue Bonds..........................................21
9.06 Feasibility Consultants.......................................22
9.07 Amendment to Act..............................................22
9.08 Joliet Training Area..........................................22
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS....................................23
10.01 Employment Opportunity........................................23
SECTION 11. ENVIRONMENTAL MATTERS.................................................23
SECTION 12. ASSIGNMENT OF AGREEMENT/TRANSFER OF THE PROPERTY......................23
12.01 Assignment...................................................23
12.02 Transfer of Property.........................................24
SECTION 13. INDEMNIFICATION.......................................................24
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT..................................24
14.01 Books and Records...................... .....................24
14.02 Inspection Rights............................................24
SECTION 15. DEFAULT AND REMEDIES..................................................25
15.01 Events of Default................. ..........................25
15.02 Remedies.....................................................25
15.03 Curative Period..............................................26
15.04 Termination of Proceedings...................................26
SECTION 16. NOTICE................................................................26
SECTION 17. MISCELLANEOUS.........................................................28
17.01 Amendment....................................................28
17.02 Entire Agreement.................. ..........................28
17.03 Limitation of Liability......................................29
17.04 Further Assurances...........................................29
17.05 Waiver.......................................................29
17.06 Enforceability of the Agreement; Remedies....................29
17.07 Disclaimer...................................................29
17.08 Headings............................................ ........30
17.09 Counterparts.................................................30
17.10 Severability.................................................30
17.11 Conflict.....................................................30
17.12 Governing Law................................................30
17.13 Form of Documents............................................30
17.14 Termination..................................................30
17.15 Binding Effect...............................................30
17.16 Force Majeure................................................30
17.17 Exhibits.....................................................30
EXHIBIT A LEGAL DESCRIPTION......................................................1
EXHIBIT B VILLAGE OF XXXXXX ECONOMIC DEVELOPMENT
PROJECT AND PLAN (DEER RUN INDUSTRIAL PARK ECONOMIC
DEVELOPMENT PROJECT AREA)...............................................1
EXHIBIT C BASE PROJECTED TAX INCREMENT............................................1
EXHIBIT D PROJECT BUDGET..........................................................1
EXHIBIT E PHASE I PUBLIC IMPROVEMENTS.............................................1
EXHIBIT F ARSENAL SITE DRAWING....................................................1
EXHIBIT G INFRASTRUCTURE IMPROVEMENTS FOR INTERMODAL FACILITIES...................1
EXHIBIT H-1 OPINION OF DEVELOPER'S COUNSEL..........................................1
EXHIBIT H-2 OPINION OF VILLAGE COUNSEL..............................................5
EXHIBIT I REQUISITION CERTIFICATE
Note Requisition Request Form...........................................1
EXHIBIT J REQUISITION CERTIFICATE
Project Reimbursement Request Form......................................1
EXHIBIT K OPTION RIGHTS REQUEST FORM..............................................1
REDEVELOPMENT AGREEMENT
This Redevelopment Agreement (this "Agreement") is made as of this 1st
day of August, 2000, by and between the Village of Xxxxxx, an Illinois home rule
municipal corporation (the "Village"), CenterPoint Intermodal LLC, an Illinois
limited liability company (as defined herein, the "Developer"), and CenterPoint
Realty Services, Inc. ("CRS", and together with the Developer, "CenterPoint").
RECITALS
A. CONSTITUTIONAL AUTHORITY: As a home rule unit of government under
Section 6(a), Article VII of the 1970 Constitution of the State of Illinois (the
"State"), the Village has the power to regulate for the protection of the public
health, safety, morals and welfare of its inhabitants, and pursuant thereto, has
the power to encourage private development in order to enhance the local tax
base, create employment opportunities and to enter into contractual agreements
with private parties in order to achieve these goals.
B. STATUTORY AUTHORITY: The Village is authorized under the provisions
of the Economic Development Project Area Tax Increment Allocation Act of 1995,
65 ILCS 110/1 ET SEQ., as amended and supplemented from time to time (the
"Act"), to, among other things, finance projects that create new job
opportunities, increase industry and commerce within the state, increase the tax
base and eradicate potentially blighting conditions through the use of tax
increment allocation financing for economic development.
C. VILLAGE BOARD AUTHORITY: To induce economic development pursuant to
the Act, the Board of Trustees of the Village (the "Village Board") adopted (1)
the following ordinances on June 12, 2000: (a) "An Ordinance of the Village of
Xxxxxx, Illinois, Approving an Economic Development Plan and Project for the
Deer Run Industrial Park Economic Development Project Area, Ordinance No. 616";
(b) "An Ordinance of the Village of Xxxxxx, Illinois, Designating the Deer Run
Industrial Park Economic Development Project Area an Economic Development
Project Area Pursuant to the Economic Development Project Area Tax Increment
Allocation Act of 1995, Ordinance No. 617"; and (c) "An Ordinance of the Village
of Xxxxxx, Illinois, Adopting Tax Increment Allocation Financing for the Deer
Run Industrial Park Economic Development Project Area, Ordinance No. 618" (the
"TIF Adoption Ordinance") and (2) adopted the following ordinances on August 7,
2000: (a) "An Ordinance of the Village of Xxxxxx, Illinois, Approving the Deer
Run Industrial Park Economic Redevelopment Project Area Redevelopment Agreement,
Ordinance No. ___"; and (b) "An Ordinance of the Village of Xxxxxx, Illinois,
Approving the Deer Run Industrial Economic Development Area TIF Fund Escrow
Agreement, Ordinance No. ___" (all of such ordinances described in this Clause C
being collectively referred to herein as the "TIF Ordinances").
D. THE PROJECT: CenterPoint intends to acquire or has acquired
approximately 2,156 acres of land (the "Property") consisting of approximately
1,800 acres of what is commonly known as the Joliet Arsenal (the "Arsenal Site")
and approximately 355 acres of what is commonly known as the Xxxxxxx Farm. The
Property is legally described on EXHIBIT A and is located entirely within the
Economic Development Project Area designated under the TIF Ordinances. As of the
date
1
hereof, CenterPoint has the right to develop the Property as set forth in the
Annexation Agreement (as hereinafter defined) and currently intends to develop
the Property with the following components:
1) an intermodal facility including rail improvements consisting
of automotive, sorting and transload facilities (the
"Intermodal Facilities");
2) a regional power plant and together with the Village, a water
treatment system and sanitary sewer treatment facility (the
"Utilities");
3) a truck stop and service plaza facility;
4) retail, including a hotel, restaurants and other commercial
uses (the "Commercial Facilities"); and
5) industrial facilities (the "Industrial Facilities").
(The above-described development and related infrastructure
improvements as may be revised from time to time as permitted herein or as
permitted by the Annexation Agreement or applicable Village Ordinance are
hereinafter referred to as the "Project".)
E. ECONOMIC DEVELOPMENT PLAN: The Project will be carried out in
accordance with applicable Village ordinances, this Agreement, the Village of
Xxxxxx Economic Development Project and Plan (Deer Run Industrial Park Economic
Development Project Area) (the "Economic Development Plan") attached hereto as
EXHIBIT B, and the Annexation Agreement, each as amended from time to time.
F. ESCROW AGREEMENT: The Village, the Developer, CRS, and Bank One,
National Association, as Escrow Agent have entered into that certain Deer Run
Industrial Park Economic Development Area TIF Fund Escrow Agreement dated as of
August 1, 2000, pursuant to which the Incremental Taxes (as defined herein)
shall be allocated for various purposes and pursuant to specified priorities as
therein provided.
G. VILLAGE FINANCING: The Village has determined to allocate
Incremental Taxes to fund various costs authorized by the Act as more fully set
forth herein, including the issuance of its Tax Increment Allocation Note(s) in
the amounts set forth in SECTION 4.03 to pay for or reimburse the Developer for
the costs of certain Economic Development Project Costs (as herein defined).
Now, therefore, in consideration of the mutual covenants and agreements
contained herein, and for other good and valuable consideration, the receipt and
sufficiency of which are hereby acknowledged, the parties hereto agree as
follows:
2
SECTION 1. RECITALS
The foregoing recitals are hereby incorporated into this Agreement by
reference.
SECTION 2. DEFINITIONS
For purposes of this Agreement, in addition to the terms defined in the
foregoing recitals, the following terms shall have the meanings set forth below:
"ACCELERATED INCREMENT" means, for any year, any Incremental Taxes
received in excess of the amounts required pursuant to Section 3.3(a) and (b) of
the Escrow Agreement to be deposited in the Program Expense Account, the
Developer Costs Account and the Taxing Districts Costs Accounts for such year.
"ACCELERATED INCREMENT ACCOUNT" shall have the meaning set forth in the
Escrow Agreement.
"ACT" shall have the meaning given thereto in the Recitals to this
Agreement.
"AFFILIATE" means any person or entity directly or indirectly
controlling, controlled by or under common control with the Developer or CRS.
"ALLOCATION PERCENTAGE" shall have the meaning given thereto in the
Escrow Agreement.
"ANNEXATION AGREEMENT" means the annexation agreement dated June 12,
2000, and recorded July 17, 2000 as Document No. R0000000000 among the Village,
the Developer, CRS, CenterPoint Properties Trust, and the United States of
America (acting by and through the Secretary of the Army, Department of the
Army) covering the Property.
"AUTHORIZED DEVELOPER REPRESENTATIVE" means any officer or manager
identified in writing by the Managers of Developer and authorized by such
writing to sign on behalf of the Developer.
"BASE PROJECTED INCREMENT" means the base projected tax increment
prepared by the Developer and set forth in column 1-1 of the attached EXHIBIT C,
as may be updated, supplemented or amended by the Developer from time to time as
to be contained in a Revenue Projection Certificate AND VERIFIED BY A
FEASIBILITY CONSULTANT, the scope of such verification to be limited to a
determination that (i) such projection is mathematically accurate and (ii) the
allocation of Incremental Taxes conforms with the priorities established in
Section 3.3 hereof.
"BASE WATER AND SEWER SYSTEM" shall have the meaning given thereto in
Section 27 of the Annexation Agreement.
"CALCULATION AGENT" means Xxxxxx Brothers, Inc. or its successor under
the Indenture.
3
"CENTERPOINT SUPPORT AGREEMENT" means that certain Standby Purchase
Agreement dated as of August 1, 2000 between CenterPoint Properties Trust and
DCCA and acknowledged and agreed to by the Village, as now or hereafter amended
or supplemented.
"CERTIFICATE" means the Certificate of Completion of Construction
described in SECTION 7.01.
"CHARITABLE CONTRIBUTIONS" means the charitable contributions to the
Village by the Developer or CRS as set forth in Section 42 of the Annexation
Agreement.
"CLOSING DATE" means the date of execution and delivery of this
Agreement by all parties hereto.
"CONCEPT PLAN" shall have the meaning given thereto in Section 16 of
the Annexation Agreement and Exhibit C thereto.
"CONSULTANT REPORT" means a report prepared by the Feasibility
Consultant which shall contain a projection of Incremental Taxes together with
one or more schedules which shall reflect the allocation of Incremental Taxes
consistent with Section 3.3 hereof.
"DCCA" means the Illinois Department of Commerce and Community Affairs.
"DCCA Loan" means the aggregate amount of the loans and grants from
DCCA or the federal Economic Development Administration to the Village to fund
water and sewer improvements in the Village pursuant to the DCCA Loan Agreement.
"DCCA LOAN AGREEMENT" means the Loan Agreements dated as of August 1,
2000 and any related grant agreements between DCCA (or, with respect to a grant
agreement, the federal Economic Development Agreement) and the Village with
respect to the DCCA Loan.
"DEER RUN INDUSTRIAL PARK PROJECT TIF FUND" means the special tax
allocation fund known as the "Deer Run Industrial Park Project Area TIF Fund"
established by the Village with the Escrow Agent pursuant to the Escrow
Agreement in connection with the Deer Run Industrial Park Economic Development
Project Area, into which the Incremental Taxes will be deposited.
"DEVELOPER" means CenterPoint Intermodal, LLC, an Illinois limited
liability company, and its successors and assigns.
"DEVELOPER ANNUAL LIMIT" shall have the meaning given thereto in the
Escrow Agreement.
"DEVELOPER COSTS ACCOUNT" shall have the meaning given thereto in the
Escrow Agreement.
"DEVELOPER SUBACCOUNT" shall have the meaning given thereto in the
Escrow Agreement.
"ECONOMIC DEVELOPMENT PROJECT AREA" means the Deer Run Industrial Park
Project Area described more fully in EXHIBIT A attached to this Redevelopment
Agreement and designated by the
4
Village pursuant to an ordinance entitled "ORDINANCE OF THE VILLAGE OF XXXXXX,
ILLINOIS DESIGNATING THE DEER RUN INDUSTRIAL PARK ECONOMIC DEVELOPMENT PROJECT
AREA" adopted on June 12, 2000, together with any amendments and supplements
thereto.
"ECONOMIC DEVELOPMENT PLAN" means the comprehensive program of the
Village for the Economic Development Project Area approved by the President and
Board of Trustees of the Village pursuant to an ordinance entitled "ORDINANCE OF
THE VILLAGE OF XXXXXX, ILLINOIS, APPROVING ECONOMIC DEVELOPMENT PLAN FOR THE
DEER RUN INDUSTRIAL PARK ECONOMIC DEVELOPMENT PROJECT AREA" adopted on June 12,
2000, together with any amendments and supplements thereto.
"ECONOMIC DEVELOPMENT PROJECT" means the real property and improvements
to be developed by the Developer within the Economic Development Project Area
pursuant hereto.
"ECONOMIC DEVELOPMENT PROJECT COSTS" means any eligible cost under the
Act paid or incurred by the Developer or any Affiliate in connection with
acquiring, constructing and equipping the Economic Development Project as
described in and not inconsistent with the Economic Development Plan; PROVIDED,
however, the following costs shall not be "eligible costs": (1) the $2,400,000
to be paid by Developer to the Xxxxxx School District; (2) the $3,600,000 to be
paid by the Developer to the Village for Phase I Public Improvements or other
public costs as provided in Section 49 of the Annexation Agreement, (3) any
improvements to the Base Water and Sewer System funded by DCCA or any other
state or federal agency; (4) private financing costs incurred by Developer or
another nongovernmental person in connection with an Economic Development
Project Costs to the extent such costs exceed 30% of the costs paid or incurred
by Developer or another nongovernmental person in a specific year, all
consistent with Section 10(e)(12) of the Act.
"EMPLOYER(S)" shall have the meaning set forth in Section 10 hereof.
"ENVIRONMENTAL LAWS" means any and all federal, state or local
statutes, laws, regulations, ordinances, codes, rules, orders, licenses,
judgments, decrees or requirements relating to public health and safety and the
environment now or hereafter in force, as amended and hereafter amended,
including but not limited to (i) the Comprehensive Environmental Response,
Compensation and Liability Act (42 U S.C. Section 9601 ET SEQ.); (ii) any
so-called "Superfund" or "Superlien" law; (iii) the Hazardous Materials
Transportation Act (49 U.S.C. Section 1802 ET SEQ.); (iv) the Resource
Conservation and Recovery Act (42 U.S.C. Section 6902 ET SEQ.); (v) the Clean
Air Act (42 U.S.C. Section 7401 ET SEQ.); (vi) the Clean Water Act (33 U.S.C.
Section 1251 ET SEQ.); (vii) the Toxic Substances Control Act (15 U.S.C. Section
2601 ET SEQ.); (viii) the Federal Insecticide, Fungicide and Rodenticide Act (7
U.S.C. Section 136 ET SEQ.); and (ix) the Illinois Environmental Protection Act
(415 ILCS 5/1 ET SEQ.).
"ESCROW AGENT" means the Escrow Agent, and any qualified entity at the
time serving as successor escrow agent under the Escrow Agreement.
5
"ESCROW AGREEMENT" means that certain Escrow Agreement dated as of
August 1, 2000, as now or hereafter amended or supplemented, establishing an
escrow, by and among the Village, the Developer, CRS, and the Escrow Agent.
"ESCROW BREAK DATE" shall mean the POS Sales Tax Transfer Date as
defined in the Escrow Agreement.
"EVENT OF DEFAULT" shall have the meaning set forth in SECTION 15
hereof.
"FEASIBILITY CONSULTANT" means a recognized consultant experienced in
tax increment financing selected by the Developer and approved by the Village
(which approval shall not be unreasonably withheld).
"GENERAL CONTRACTOR" means the general contractor(s) hired by the
Developer.
"HAZARDOUS MATERIALS" means any toxic substance, hazardous substance,
hazardous material, hazardous chemical or hazardous, toxic or dangerous waste
defined or qualifying as such in (or for the purposes of) any environmental law,
or any pollutant or contaminant, and shall include, but not be limited to,
petroleum (including crude oil), any radioactive material or by-product
material, polychlorinated biphenyls and asbestos in any form or condition.
"HOME RULE SALES TAX" shall have the meaning set forth in SECTION 4.06
hereof.
"IDOT" means the Illinois Department of Transportation.
"INCREMENTAL TAXES" means the ad valorem taxes, if any, arising from
the tax levies upon taxable real property in the Economic Development Project
Area by any and all taxing districts or municipal corporations having the power
to tax real property in the Economic Development Project Area, which taxes are
attributable to the increase in the then current equalized assessed valuation of
each taxable lot, block, tract or parcel of real property in the Economic
Development Project Area over and above the Certified Initial Equalized Assessed
Value of each such piece of property.
"INDENTURE" means that certain Indenture relating to the TIF Notes to
be entered into between the Village and the Trustee, as hereafter amended or
supplemented.
"INITIAL ORIGINAL PRINCIPAL AMOUNT" shall have the meaning set forth in
SECTION 4.02(a) hereof.
"INTEREST COMMENCEMENT Date" shall have the meaning given thereto in
the Indenture.
"JOLIET TRAINING AREA" means the training facility owned and operated
by the United States Department of the Army located north of the Deer Run
Industrial Park.
"MATERIAL BREACH" shall have the meaning given thereto in Section
15.02(a) hereof.
6
"NEEDS CERTIFICATE" means a certificate prepared by Developer or the
Village projecting demand for water and/or sewer services in excess of the
capacity for the Base Water and Sewer System to which such party is entitled
under the Annexation Agreement, supported by an independent consulting
engineer's report, certification or opinion and taking into account projected
development schedules over the term of this Agreement.
"NOTE REQUISITION REQUEST" means a request delivered by an Authorized
Developer Representative in substantially the form attached hereto as EXHIBIT I.
"NOTEHOLDERS" shall have the meaning set forth in SECTION 9.03 hereof.
"OPTION RIGHTS" means the rights created by SECTION 4.2 of the
Indenture to require all or a portion of the Series 2000A Notes to be tendered
as therein provided.
"OPTION RIGHTS REQUEST" means a request executed by an Authorized
Developer Representative in substantially the form of the attached Exhibit K.
"PHASE I COMMITMENTS" shall consist of payment by the Developer the
following: (1) $2,400,000 to the Xxxxxx School District 203 to be used for any
legal capital or operating cost of the School District, such amount to be paid
in the amounts and at the times provided in the Annexation Agreement; (2)
$3,600,000 to the Village in the amounts and at the times provided in the
Annexation Agreement for any Village operating costs or public improvements in
the Village, including, but not limited to, a new Village Hall and improvements
to Mississippi Street and/or Chicago Avenue, such costs to be incurred by or on
behalf of the Village pursuant to plans and specifications and a construction
contract approved by the Village Board (a copy of which is to be filed with
Developer for informational purposes); provided, Developer's payment obligation
shall not be conditioned on, and Developer shall have no right of approval with
respect to, such invoices, plans and specifications or construction contracts;
(3) all reasonably necessary costs of completing the Base Water and Sewer System
to the extent such costs exceed the DCCA Loan and any other federal or State
financial assistance, provided, that the plans and specifications, construction
contracts, contractor and construction time table for the Base Water and Sewer
System are reasonably acceptable to Developer; (4) the Village share of the cost
of the improvement of local roads, such cost presently estimated to be
$5,500,000; (5) the portion of the Will County local share of the improvements
to local County roads (less any amounts available from IDOT or any other
governmental agency), such local share presently estimated to be $18,300,000;
and (6) the CenterPoint Support Agreement, all of which Phase I Commitments are
subject to the provisions of the Annexation Agreement.
"PHASE I PUBLIC IMPROVEMENTS" means those public improvements set forth
on Exhibit E hereto.
"Phase II Public Infrastructure Account" means shall have the meaning
given thereto in Article I of the Escrow Agreement.
7
"PLEDGE AGREEMENT" means the Pledge Agreement dated as of the date of
the Indenture to be entered among the Village, the Developer, and the Escrow
Agent, as now or hereafter amended or supplemented.
"PLEDGED SUBORDINATED INTEREST" shall have the meaning set forth in
SECTION 4.07 hereof.
"P.O.S. Sales Tax" shall have the meaning set forth in SECTION 4.06
hereof.
"P.O.S. SALES RECEIPTS" means the P.O.S. Sales Taxes received by the
Village.
"PROJECT BUDGET" means the budget attached hereto as EXHIBIT D, showing
the total cost of the Project, furnished by the Developer, in accordance with
Section 3.02 hereof, as now or hereafter modified.
"PROJECT REIMBURSEMENT REQUEST" means a request executed by an
Authorized Developer Representative in substantially the form attached hereto as
Exhibit J.
"QUALIFIED PERSON" means any entity which is, or is owned or controlled
by, a pension fund, insurance company, financial institution, a person with a
long-term unsecured debt rating of BBB- or higher and who owns or leases at
least 500,000 square feet of property similar to the Property.
"REQUISITION FORM" shall be substantially in the forms of EXHIBIT I,
EXHIBIT J and EXHIBIT K hereto.
"REVENUE NOTE ORDINANCE" means the ordinance adopted by the President
and the Board of Trustees of the Village on August 7, 2000 entitled: "AN
ORDINANCE approving two Revenue Obligation Loan Agreements with, and a letter
agreement as to grants from, the Illinois Department of Commerce and Community
Affairs and authorizing and providing for the issuance of one or more Taxable
Revenue Notes (Combined Waterworks and Sewerage System), Series 2000, of the
Village of Xxxxxx, Will County, Illinois, in a principal amount not to exceed
$14,500,000 in connection therewith for the purpose of defraying the cost of
improving the waterworks and sewerage system of the Village and refunding and
defeasance of certain prior obligations of the Village related thereto, and
prescribing details of said Notes."
"REVENUE PROJECT CERTIFICATE" shall be a certificate prepared by the
Developer for the determination of Base Projected Increment pursuant to the
terms hereof and the Indenture.
"ROAD PROJECTS" means those transportation infrastructure improvements
substantially as described in a letter from the Illinois Department of
Transportation to the Village and Will County.
"SECTION 15D Bonds" shall have the meaning given thereto in the Revenue
Note Ordinance.
"SUBORDINATED DEVELOPER INTEREST" shall have the meaning given thereto
in Section 4.07 hereof.
8
"TAXING DISTRICTS" means each school district or other unit of
government municipal entity with the jurisdiction to levy and which actually
levies ad valorem property taxes within the Economic Development Project Area.
"TAXING DISTRICTS COSTS ACCOUNT" shall have the meaning given thereto
in the Escrow Agreement.
"TERM OF THE AGREEMENT" means the period of time commencing on the
Closing Date and ending on the date when all Economic Development Project Costs
and all amounts evidenced by the TIF Notes have been paid and all excess
Incremental Taxes have been distributed in accordance with this Agreement, the
Escrow Agreement, the Indenture and the TIF Ordinances, but in no event later
than June 12, 2023.
"TIF NOTE ORDINANCE" means the Village ordinance authorizing the
issuance of TIF Notes.
"TIF NOTES" means the Village of Xxxxxx Illinois Tax Increment
Allocation Revenue Note(s) (Deer Run Industrial Park Project) to be in a form
and issued from time to time pursuant to the TIF Note Ordinance and the
Indenture, the proceeds of which will be used to pay for or reimburse the
Developer for Economic Development Project Costs pursuant to this Agreement.
"TIF-FUNDED IMPROVEMENTS" means that portion of the Economic
Development Project which is funded with proceeds of the TIF Notes or directly
with Incremental Taxes pursuant to the Act and in accordance with this
Redevelopment Agreement.
"TIF ORDINANCES" shall have the meaning given thereto in the Preambles.
"TRUSTEE" means Bank One, National Association, as Trustee under that
certain Trust Indenture to be entered into by the Village and such Trustee
concerning the TIF Notes.
"VILLAGE ADMINISTRATIVE COSTS" shall have the meaning given to
"Administrative Costs" in the Escrow Agreement.
"VILLAGE ANNUAL LIMIT" shall have the meaning given to it in the Escrow
Agreement.
SECTION 3. THE PROJECT
3.01 THE PROJECT.
(a) Acquisition:
CRS has acquired the Xxxxxxx Farm and the Developer, CRS or an
Affiliate will acquire that portion of the Arsenal Site shown on the
attached EXHIBIT F as T-1.
9
(b) Intermodal Facilities.
The Developer has entered into a Lease Agreement with
Burlington Northern Santa Fe Railroad Company (the "Railroad Company")
pursuant to which the Developer has agreed to build the Intermodal
Facilities, including the infrastructure improvements listed on EXHIBIT
G, and the Railroad Company has agreed to lease certain portions and
acquire certain portions of the Intermodal Facilities from the
Developer.
(c) Industrial/Commercial Facilities.
The Developer intends to develop the Property over time and
from time to time as contemplated generally by the Economic Development
Plan (attached hereto as EXHIBIT B) or as permitted by the Annexation
Agreement (including, without limitation, Section 17 thereof), such
development being dependent upon the Developer's determination of the
existence of a market for such permitted uses and the economic
feasibility thereof.
(d) The Utilities.
(i) The Village and CenterPoint have agreed in the
Annexation Agreement as to the design, financing,
construction, capacity, and rates of the Base Water
and Sewer System.
(ii) The Village or its designee shall be the operator for
the Base Water and Sewer System with duties and
responsibilities to be mutually agreed upon as a
condition of the DCCA Loan.
(iii) In the event that a power plant is to be constructed
on the Property or in connection with the Project,
the Village shall have no obligation to finance an
expansion of the Base Water and Sewer System to
accommodate such power plant unless the Developer
and/or owner of such power plant provides the funding
for such expansion and except as provided in Section
9.05 hereof. However, if such funding is provided,
the Village shall be obligated to expand the Base
Water and Sewer Systems to provide the necessary
water and sewer requirement for such plant.
3.02 PROJECT BUDGET. The Developer has prepared and furnished
the Project Budget showing total estimated costs for the Project in an amount of
approximately $941,183,000. The Project Budget includes the Economic Development
Project Costs to be paid initially from the proceeds of the TIF Notes or
directly from Incremental Taxes.
3.03 PHASE I COMMITMENTS/CHARITABLE CONTRIBUTIONS.
(a) The Village hereby acknowledges that CenterPoint has
committed to providing the Charitable Contributions as set forth in
Section 42 of the Annexation Agreement.
10
(b) In addition, CenterPoint shall provide the Phase I
Commitments as described in the following Sections of the Annexation
Agreement Section 27 (with respect to the Base Water and Sewer System);
Section 29 (with respect to improvements to local roads); and Section
49 (with respect to certain initial payments and other actions).
(c) CenterPoint hereby acknowledges and agrees that its
obligation under the Annexation Agreement to pay all reasonably
necessary costs of completing the Base Water and Sewer System shall
continue to be applicable to and binding upon CenterPoint
notwithstanding any failure of the Illinois General Assembly to make
appropriations available to DCCA as described in Section 10.13 of the
DCCA Loan Agreement or other limitation, condition or term which
relates to tax increment financing set forth in Section 4.02 herein,
the Annexation Agreement, the Revenue Note Ordinance, this
Redevelopment Agreement or other related documents. Under no
circumstances (other than as set forth below in this Section 3.03)
shall the Village be required to provide for any funding of Base Water
and Sewer System capital costs should DCCA fail to provide, through
loans and grants, such costs or if costs exceed amounts deemed
necessary by CenterPoint and the Village engineer unless CenterPoint
provides all funds necessary for such capital costs subject to
reimbursement or repayment as contained herein.
(d) To provide certainty of funding for the costs associated
with clauses (2), (3), (4) and (5) in the definition of "Phase I
Commitments," Developer shall cause to be provided an evergreen annual
letter of credit in the amount of $3,000,000 against which the Village
may draw to pay costs of the above-listed Phase I Commitments. In lieu
of such an evergreen annual letter of credit, the Developer may provide
such funding source or mechanism as the Village may, in its reasonable
judgment, find acceptable.
To the extent that funding is or becomes available for any Phase I
Public Improvement costs (in whole or in part) from any federal, state or local
source, the Village agrees to: (i) use its best efforts to seek and obtain such
funding; (ii) agree to the lowest cost financing alternatives (unless the
Developer agrees to the contrary); and (iii) shall cooperate fully with the
Developer and such funding sources so long as the terms and conditions relating
thereto are reasonably satisfactory to the Village and do not materially
adversely affect the Village's ability to operate and maintain such
Improvements. If such funding is in the form of a grant rather than a loan, it
shall be deemed reasonably satisfactory to the Village and the Developer unless
there are extraordinary requirements which are specifically identified by the
Village or the Developer as being materially adverse to the Village and the
Project. Any such federal, state or local funding shall be used at the election
of the Village either: (A) to the maximum extent feasible to redeem the TIF Note
or Notes issued with respect to the costs allocable to such federal, state or
local funding (or to fund a defeasance account for retirement of the TIF Note(s)
at the earliest optional call date) or (B) to reimburse the Developer for any
such costs paid for by the Developer, together with interest and any other costs
or expenses paid or incurred by the Developer in connection therewith. Any
redemption or defeasance deposit described in (A) above shall not be counted
against the First Lien Developer Annual Limit for the year of application.
11
3.04 CONCEPT PLAN. The Village acknowledges that the Developer has
delivered the Concept Plan to the Village.
3.05 CONSTRUCTION OF TIF FUNDED IMPROVEMENTS. The Developer will, or
will cause, the TIF Funded Improvements to be built, installed and constructed
in substantial compliance with the Concept Plan. The Developer will not commence
construction of a component of the TIF Funded Improvements until the Developer
has obtained all necessary Village permits and zoning approvals legally required
to be obtained prior to commencement of construction of such component. In
addition to the contingencies set forth elsewhere herein or in the Annexation
Agreement, the Developer's obligation to complete the TIF Funded Improvements
shall be contingent upon and subject to Developer's right to terminate as set
forth in Section 49 of the Annexation Agreement.
3.06 PROGRESS REPORTS AND SURVEY UPDATES. The Developer shall provide
the Village with written quarterly progress reports detailing the status of the
Project, including a revised completion date, if necessary.
3.07 SPECIAL SERVICE AREA. CenterPoint acknowledges the agreements it
has made with respect to the creation of certain Special Service Areas as set
forth in Section 31 of the Annexation Agreement. The Developer shall be entitled
to cause abatement of any levy on an annual basis by making or causing to be
made payments in lieu of taxes for such purposes. The Developer shall also be
entitled to notice of the proposed budgeted costs and services and to the right
to consult and advise the Village as to reasonable levels of service, costs and
alternatives.
SECTION 4. FINANCING
4.01 TOTAL PROJECT COSTS AND SOURCES OF FUNDS. (a) The cost of
the Project is estimated to be $941,183,000. The Developer intends to pay the
costs of the Project from the financial assistance provided pursuant to this
Agreement and other sources of funds available to Developer and its Affiliates.
(b) In order to finance the costs of the TIF Funded Improvements, which will
comprise a significant portion of the Project, the Village hereby agrees to
provide the financial assistance set forth in this Section 4. (c) The parties
hereto acknowledge and agree that the Project would not reasonably be developed
without the adoption of the Economic Development Plan by the Village and the
financial assistance provided therein and pursuant to this Agreement.
4.02 TIF NOTE(S)
(a) The Village hereby agrees to issue, authenticate and deliver to the
Developer or its registered assigns, in exchange for the payment or incurrence
by Developer or any Affiliate thereof of Economic Development Project Costs
evidenced as described in this Section 4.02 and the Term Sheet attached as
Exhibit D to the Annexation Agreement, one or more TIF Note(s) or series of TIF
Note(s) in an aggregate original principal amount equal to sum of (i)
$100,000,000 plus (ii) any cost of the Road Projects paid by Developer or an
Affiliate which exceeds $5,500,000 plus (iii) any cost of the Base Water and
Sewer System not funded with the DCCA Loan plus (iv) any other costs mutually
agreed to between the Village and Developer (the "Initial Original Principal
Amount"); provided, however, any increase described in clause (ii) shall not
exceed $18,000,000 and
12
the aggregate increase described in clauses (ii) and (iii) shall not exceed
$25,000,000. The Village agrees to issue one or more TIF Note(s) or series of
TIF Note(s) subject to the above limitation in aggregate original principal
amount and such TIF Notes shall be deemed purchased by Developer by the payment
or incurrence of the Economic Development Project Costs which shall be evidenced
as provided in Section 4.02 hereof. The principal amount of the TIF Note(s)
shall accrete and appreciate at ten percent (10%) per annum, compounded
semi-annually until the earlier of the Interest Commencement Date or the date
interest accrued on the TIF Notes on a current (semi-annual basis).
(b) The Developer or its registered assigns shall, at the
option of the Developer, be entitled to have the TIF Notes issued from time to
time, or the original principal amount of TIF Notes theretofore issued to be
increased from time to time, in an original principal amount not to exceed the
limitations described herein, by the payment or incurrence by Developer or any
Affiliate of Economic Development Project Costs and the submission of a Note
Requisition Request to the Trustee in form of EXHIBIT I hereto. The original
principal amount of the TIF Notes shall be increased dollar-for-dollar for the
Economic Development Project Costs so evidenced by any such Note Requisition
Request, subject to the limitation described herein. The TIF Note(s) will be
issued in such form and subject to such terms and conditions as shall be
provided in the TIF Note Ordinance, the Indenture and consistent with the term
sheet attached as EXHIBIT D to the Annexation Agreement.
(c) The Developer expects that Developer and its Affiliates
will incur Economic Development Project Costs in excess of the Initial Original
Principal Amount. The Village agrees that Incremental Taxes on deposit from time
to time in the Developer Cost Subaccount of the Developer Costs Account under
the Indenture shall be made available exclusively for payment of Economic
Development Project Costs. For any calendar year in which the principal of and
interest and other amounts payable with respect to the TIF Notes is less than
the then applicable Developer Annual Limit, the Developer shall be entitled to
be reimbursed for Economic Development Project Costs on a dollar-for-dollar
basis (but in an amount which does not exceed the applicable Developer Annual
Limit except to the extent such costs are not subject to the Developer Annual
Limit as elsewhere provided herein or in the Escrow Agreement) pursuant to a
properly completed and filed Project Reimbursement Request to the Trustee in the
form of EXHIBIT J hereto.
(d) In addition to the foregoing, the Developer shall be
entitled to be reimbursed for payment or incurrence of Economic Development
Project Costs (without regard to the applicable Developer Annual Limit) by the
issuance of certificates evidencing Option Rights as shall be provided under the
Indenture upon a properly completed and filed Option Rights Request to the
Trustee in the form of EXHIBIT K hereto. For each $6.00 of Economic Development
Project Costs so incurred and described in an Option Rights Request, Developer
or its registered assign shall be entitled to receive an Option Rights
Certificate with respect to $10.00 original principal amount of TIF Notes. The
Option Rights Certificates shall be deemed purchased by Developer by the payment
or incurrence of the Economic Development Project Costs which shall be evidenced
as provided by this Section 4.02(d).
13
(e) Incremental Taxes on deposit in the Developer
Subaccount of the Accelerated Increment Account shall be disbursed from time
to time at the written request of an Authorized Developer Representative in
the form of EXHIBIT J filed with the Escrow Agent to pay any costs paid or
incurred from time to time by Developer or any Affiliate for infrastructure
or other Economic Development Project Costs permitted under the Act.
(f) The Developer at its option shall be entitled to receive
credit or reimbursement for the payment or incurrence of Economic Development
Project Costs under any of subparagraphs (b), (c), (d) or (e), but shall not
receive payment or credit for any particular dollar of cost under more than one
of such subparagraphs.
(g) The Indenture shall provide that the Trustee shall not
approve a Project Reimbursement Request unless it first determines that payment
of such amount will not impair the rights of the holders of the TIF Notes to
receive principal of and interest on the TIF Notes as and when due. If the
Trustee approves a Project Reimbursement Request, then the Trustee shall
authorize the prompt payment of funds from the Developer Costs Account to the
Developer and promptly advise the Escrow Agent and Village of such payment.
(h) In the TIF Note Ordinance and the Indenture, the Village
shall authorize the Calculation Agent to establish, among other things, an
Interest Commencement Date, a mandatory tender or tender option period,
mandatory tender prices, a mandatory sinking fund schedule for each advance
described in subparagraph (b) hereof and such other terms as are permitted
hereunder, under the Indenture or under the term sheet attached as Exhibit D to
the Annexation Agreement, such Interest Commencement Date and mandatory sinking
fund schedule to be based upon the most recent Revenue Projection Certificate
and the resulting amounts of Incremental Taxes expected to be available to pay
scheduled principal and interest due with respect to such advance and all prior
advances theretofore approved, assuming a debt service coverage ratio of 1.0x,
(but taking into account whether the amount of Incremental Taxes available for
such purposes increases over time) and a twenty year term for that portion of
the TIF Note which represents such advance, all as set forth in more detail in
the Indenture.
(i) The TIF Note(s) may be held by one or more business
entities formed by CenterPoint Properties Trust or an Affiliate or subsidiary
thereof and/or one or more other investors, provided that any such investor
shall be either: (a) an Accredited Investor (as defined in Rule 501 of
Regulation D under the Securities Act of 1933, as amended) or (b) a Qualified
Institutional Buyer (as defined in Rule 144A under the Securities Act of 1933,
as amended) or, if neither (a) nor (b), then such investor shall be subject to
approval by the Village, which shall not be unreasonably withheld. The TIF
Note(s) shall be freely transferable and the Developer or any other noteholder
may freely issue one or more identical or different participations therein to
any other person provided that if the TIF Note(s) (or any participation therein)
is to be transferred to (a) a person other than the noteholder, (b) an affiliate
of the Developer or any Noteholder, (c) an investor in the Project (but only if
such investor is an Accredited Investor or Qualified Institutional Buyer or is
otherwise reasonably acceptable to the Village), or (d) an Accredited
Investor(s) or a Qualified Institutional Buyer(s), then the initial such
transfer may only occur following completion of a financial feasibility
14
study or forecast prepared by a recognized consultant selected by the Developer
and approved by the Village (which approval shall not be unreasonably withheld).
(j) The Developer, or its assigns, shall have the right to
cause the Village to execute and deliver such further documents or instruments
as Developer requires in order to: (i) permit the TIF Note(s) to be exchanged
for multiple TIF Note(s) or otherwise issued or converted in part or in whole
into tranches or series which may bear interest at the same or different rates
(with the weighted average interest rate to always equal ten percent (10%) per
annum); (ii) provide multiple tranches or liens relating to the Incremental
Taxes allocable to the Developer Costs Account in order to maximize proceeds or
provide flexibility to Developer; or (iii) provide for separate serialization of
TIF Note(s) or maturities. In addition, subject to the reasonable consent of the
Village, the Developer may make or request the Village to make such other or
further changes to the terms relating to the TIF Note(s) which the Developer may
determine to be necessary or appropriate to promote the development of the
Project and provide incentives therefor, which changes relating to the interest
rate, lien status and other provisions, to the maximum extent permitted by law,
shall be approved by the initial resolutions and ordinances of the Village and
shall not require any further legislative act by the Village, provided, that any
such change shall not increase the aggregate cumulative amount of Incremental
Taxes to be allocated to the Developer Costs Account or dilute the rights or
security of the Village or Taxing District's to the Incremental Taxes allocated
to the Taxing Districts Account or the Phase II Public Infrastructure Account.
The Village also agrees to cooperate with the Developer and to execute such
further documents or other instruments as may be reasonably necessary to permit
the securitization of the TIF Note(s) or any transfer to a permitted assignee.
4.03 COST OVERRUNS. The Developer shall be solely responsible for costs
incurred by Developer in excess of the financial assistance provided herein.
4.04 BASE PROJECTED INCREMENT; UPDATED PROJECTIONS; ALLOCATION OF
INCREMENTAL TAXES.
(a) The Developer's current Base Projected Increment is set
forth in EXHIBIT C attached hereto. The Developer shall be authorized to update
the Base Projected Increment from time to time and the Village shall be deemed
to approve such updated Base Projected Increment upon verification of such
projections by the Feasibility Consultant in the manner specified in the
definition of "Base Projected Increment." The Base Projected Increment, as
updated from time to time, shall be the basis for the "Revenue Projection
Certificate" as defined in the Indenture.
(b) Incremental Taxes will be allocated by the Escrow Agent to
the various purposes and in the order of priority as set forth in Section 3.3 of
the Escrow Agreement.
4.05 VILLAGE ADMINISTRATIVE COSTS; USE OF INCREMENTAL TAXES BY VILLAGE
AND TAXING DISTRICTS.
(a) To the extent that the Village incurs Administrative Costs
in calendar year 2000, the Developer shall pay such Administrative Costs up to a
maximum equal to the pro-rata portion of $100,000 based on the number of months
remaining in calendar year 2000 on the date of
15
this Agreement. Thereafter, Administrative Costs of the Village shall be payable
out of Incremental Taxes solely as provided in, and subject to, the Escrow
Agreement.
(b) Incremental Taxes deposited in the Taxing Districts Costs
Account, the Phase II Public Infrastructure Account or the Village Subaccount of
the Accelerated Increment Account shall be disbursed from time to time at the
written certification of an Authorized Village Representative delivered to the
Escrow Agent to pay any costs permitted by the Act, including (1) capital or
operating costs of any Taxing District resulting from the Project necessarily
incurred or estimated to be incurred by a Taxing District in the furtherance of
the objectives of the Project to the extent that the Village, by written
agreement, accepts and approves such costs in an amount not to exceed the
Village Annual Limit and (2) any Economic Development Project Costs paid or
incurred by Developer or any affiliate thereof. Developer hereby agrees that, to
the extent that it has paid or incurred Economic Development Project Costs for
which it has not sought reimbursement and does not intend to seek reimbursement
for under Section 4.02 hereof, at the written request of the Village the
Developer shall agree to be reimbursed for such costs under this Section 4.05
out of the Phase II Public Infrastructure Account in exchange for an undertaking
by Developer to provide funding for or incur costs for the benefit of the
Village so long as Developer is held harmless by the Village for such
undertaking.
(c) The Village may accumulate Incremental Taxes in the Taxing
Districts Costs Account pending expenditure or other application towards any
eligible costs, subject only to any statutory requirement to either spend
Incremental Taxes or declare such Incremental Taxes to be "Surplus." At any time
or from time to time, the Village may declare all or any portion of the
Incremental Taxes in the Taxing Districts Costs Account up to the Village Annual
Limit to be "Surplus" (as defined in the Act).
4.06 USE OF P.O.S. SALES TAX. The Village agrees to impose a "Home
Rule Sales Tax". The Developer hereby agrees to cause its contractors to
establish a point of sale location within the Village. The Village agrees to
levy the Home Rule Sales Tax with respect to such sales of construction
materials. The Village shall have no obligation to continue the Home Rule
Sales Tax after June 1, 2015.
4.07 PLEDGE AGREEMENT. The Village acknowledges and agrees that the
Developer shall have the right to pledge, deposit or transfer all of its
right, title and interest in and to the TIF Notes and payments thereunder in
connection with one or more financings or other arrangements; provided,
however, until the Phase I Commitments have been satisfied, either Developer
or an Affiliate shall retain a subordinated interest in the TIF Notes which
shall entitle Developer and/or Affiliate to receive payments of principal and
interest thereon of not less than ten percent (10%) of the original principal
amount of the TIF Notes (the "Subordinated Developer Interest"). Developer
shall pledge such Subordinated Interest (herein, the "Pledged Subordinated
Interest") to the Village pursuant to a Pledge Agreement to secure
Developer's performance of the Phase I Commitments.
4.08 PURCHASE OF SECTION 15D BONDS. Upon thirty (30) days prior written
notice, the Developer shall purchase Section 15D Bonds from the Village in an
amount equal to any and all costs of the Base Water and Sewer System for which
the Village does not receive funding from
16
DCCA because of an Appropriation Shortfall (as such term is defined in the
Revenue Note Ordinance). The obligation described in this Section 4.08 shall not
be enforced by the Village any earlier than November 15, 2001. Developer shall
be entitled to a release from the obligation to purchase Section 15D Bonds as
described in this Section 4.08 if the Village receives at least $25,000,000 in
aggregate loans and grants from DCCA or other state or federal sources.
SECTION 5. CONDITIONS PRECEDENT
The following conditions shall be complied with within the time periods
set forth below or, if no time period is specified, prior to the Closing Date:
5.01 OTHER GOVERNMENTAL APPROVALS. The Developer shall have secured all
other necessary approvals and permits required to be obtained as and when
necessary for commencement of construction, by any state, federal, or local
statute, ordinance or regulation.
5.02 [INTENTIONALLY OMITTED].
5.03 INSURANCE. Upon taking title to the Property, the Developer, at
its own expense, shall insure the Property in a manner and in amounts which are
reasonable and typical for projects similar to the Project. In addition, the
Developer has agreed in the Annexation Agreement (Section 42G) to name the
Village as an additional insured on the environmental liability insurance policy
that it intends to purchase.
5.04 LEGAL OPINIONS. On the Closing Date, CenterPoint shall furnish the
Village and the Village shall furnish CenterPoint with opinions of counsel,
substantially in the forms attached hereto as EXHIBIT H-1 AND H-2. In addition,
upon the first date on which a TIF Note is issued under the Indenture, the
Developer shall obtain an opinion of nationally recognized bond counsel
(currently anticipated to be Altheimer & Xxxx) as to the tax exemption of the
TIF Note(s) (the "Tax Opinion"). The Village shall be entitled to engage a firm
of nationally recognized bond counsel reasonably acceptable to the Developer for
the purpose of providing an opinion solely to the Village that it believes it is
reasonable for the Village to rely upon such Tax Opinion (the "Comfort
Opinion"). The Developer shall pay the fees and expenses of counsel providing
the Comfort Opinion for actual time devoted to such opinion based on such firm's
standard hourly rates and such fees and expenses shall not exceed $40,000.
5.05 SEC FILINGS. CenterPoint shall provide the Village with any
CenterPoint Properties Trust filings with the Securities and Exchange Commission
(SEC) as and when such filings, if any, are available.
5.06 CORPORATE DOCUMENTS. On the Closing Date, the Developer shall
provide a copy of its Articles or Certificate of Organization containing the
original certification of the Secretary of State of its state of organization
and certificates of good standing from the Secretary of State of its state of
organization and from the State of Illinois.
17
5.07 PRECONDITIONS OF DISBURSEMENT. As of the date of submission of
each Requisition Form, the Developer shall be deemed to certify to the Village
that:
(a) the total amount of the disbursement request represents the actual
amount payable to (or paid to) the General Contractor and/or subcontractors who
have performed work on the TIF Funded Improvements or on the Project, and/or
their payees;
(b) the Developer has approved all work and materials for the current
disbursement request, and such work and materials conform to the Concept Plan as
such may be amended if the request is in connection with TIF Funded
Improvements;
(c) the representations and warranties contained in this Agreement are
true and correct in every material respect and the Developer is in compliance
with all covenants contained herein; and
(d) no Event of Default under this Agreement exists.
SECTION 6. AGREEMENTS WITH CONTRACTORS
6.01 GENERAL CONTRACTOR AND SUBCONTRACTORS. The Developer shall submit
to the Village copies of any construction contract to which the Developer is a
party for the TIF Funded Improvements prior to the disbursement of TIF Note(s)
Proceeds or Incremental Taxes. Photocopies of all subcontracts to which the
Developer is a party, if any, entered or to be entered into in connection with
the TIF Funded Improvements shall be provided to the Village within five (5)
business days of the execution thereof.
SECTION 7. COMPLETION OF CONSTRUCTION
7.01 CERTIFICATE OF COMPLETION OF CONSTRUCTION. Upon completion of the
construction of the TIF Funded Improvements from time to time in accordance with
the terms of this Agreement and the Annexation Agreement, and upon the
Developer's written request, the Village shall issue to the Developer a
Certificate of Completion ("Certificate"), in recordable form certifying that
the Developer has fulfilled its obligation to complete the TIF Funded
Improvements in accordance with the terms of this Agreement. The Village shall
respond to the Developer's written request for a Certificate within thirty (30)
days by issuing either a Certificate or a written statement detailing the ways
in which the TIF Funded Improvements do not conform to this Agreement or have
not been satisfactorily completed, and the measures which must be taken by the
Developer in order to obtain the Certificate. The Developer may resubmit a
written request for a Certificate upon completion of such measures.
7.02 EFFECT OF ISSUANCE OF CERTIFICATE; CONTINUING OBLIGATIONS. The
Certificate relates only to the construction of the TIF Funded Improvement, and
upon its issuance, the Village will certify that the terms of the Agreement
specifically related to the Developer's obligation to complete such activities
have been satisfied.
18
7.03 NOTICE OF EXPIRATION OF TERM OF AGREEMENT. Upon the expiration of
the Term of the Agreement, the Village shall provide the Developer, at the
Developer's written request, with a written notice in recordable form stating
that the Term of the Agreement has expired.
SECTION 8.
COVENANTS/REPRESENTATIONS/WARRANTIES OF THE DEVELOPER
8.01 GENERAL. The Developer represents, warrants and covenants, as of
the date of this Agreement and as of the date of each disbursement of TIF
Note(s) Proceeds or Incremental Taxes hereunder, that:
(a) the Developer is an Illinois limited liability company duly
organized, validly existing, qualified to do business in Illinois, and licensed
to do business in any other state where, due to the nature of its activities or
properties, such qualification or license is required;
(b) the Developer has the right, power and authority to enter into,
execute, deliver and perform this Agreement;
(c) the execution, delivery and performance by the Developer of this
Agreement has been duly authorized by all necessary limited liability company
action, and does not and will not violate its Articles of Organization, by-laws
or any applicable provision of law, or constitute a breach of, default under or
require any consent under any agreement, instrument or document to which the
Developer is now a party or by which the Developer is now or may become bound;
(d) the Developer is now and for the Term of the Agreement shall remain
solvent and able to pay its debts as they mature;
(e) there are no actions or proceedings by or before any court,
governmental commission, board, bureau or any other administrative agency
pending, threatened or affecting the Developer which would impair its ability to
perform under this Agreement;
(f) the Developer has and shall from time to time maintain all
government permits, certificates and consents (including, without limitation,
appropriate environmental approvals) necessary to conduct its business and to
commence construction, complete and operate the Project; and
(g) the Developer is not in default with respect to any indenture, loan
agreement, mortgage, deed, note or any other agreement or instrument related to
the borrowing of money to which the Developer is a party or by which the
Developer is bound which would adversely effect its ability to perform under
this Agreement.
8.02 ECONOMIC DEVELOPMENT PLAN. The Developer represents that the
Project is and shall be in compliance with all of the terms of the Economic
Development Plan.
19
8.03 EMPLOYMENT OPPORTUNITY. The Developer covenants and agrees to
abide by the terms set forth in SECTION 10 hereof.
8.04 PREVAILING WAGE. The Developer covenants and agrees to pay, and to
contractually obligate and cause the General Contractor and each subcontractor
to pay, the prevailing wage rate as ascertained by the Illinois Department of
Labor (the "Department"), to all employees that perform work related to the TIF
Funded Improvements. All such contracts shall list the specified rates to be
paid to all laborers, workers and mechanics for each craft or type of worker or
mechanic employed pursuant to such contract. If the Department revises such
prevailing wage rates, the revised rates shall apply to all such contracts. Upon
the Village's request, the Developer shall provide the Village with copies of
all such contracts entered into by the Developer or the General Contractor to
evidence compliance with this SECTION 8.04.
8.05 DEVELOPER'S LIABILITIES. The Developer shall not enter into any
transaction that would materially and adversely affect its ability to perform
its obligations hereunder or to repay any material liabilities or perform any
material obligations of the Developer to any other person or entity. The
Developer shall immediately notify the Village of any and all events or actions
which may materially affect the Developer's ability to carry on its business
operations or perform its obligations under this Agreement or any other
documents and agreements.
8.06 COMPLIANCE WITH LAWS. To the best of the Developer's knowledge,
after diligent inquiry, the Property and the Project are and shall be in
compliance with all applicable federal, state and local laws, statutes,
ordinances, rules, regulations, executive orders and codes pertaining to or
affecting the Project and the Property.
8.07 COMPLIANCE WITH AGREEMENTS. The Developer will comply with all
contracts, licenses, permits and agreements relating to the TIF Funded
Improvements. Developer shall immediately notify the Village in writing of the
occurrence of any default under any such contract, license, permit or agreement.
8.08 SURVIVAL OF COVENANTS. All warranties, representations,
covenants and agreements of the Developer contained in this SECTION 8 and
elsewhere in this Agreement shall be true, accurate and complete at the time
of the Developer's execution of this Agreement, and shall survive the
execution, delivery and acceptance hereof by the parties hereto and (except
as provided in SECTION 7 hereof upon the issuance of a Certificate) shall be
in effect throughout the Term of the Agreement.
SECTION 9. COVENANTS/REPRESENTATIONS/WARRANTIES OF VILLAGE
9.01 GENERAL COVENANTS. The Village represents that it has the
authority as a home rule unit of local government to execute and deliver this
Agreement and to perform its obligations hereunder.
9.02 SURVIVAL OF COVENANTS. All warranties, representations, and
covenants of the Village contained in this SECTION 9 or elsewhere in this
Agreement shall be true, accurate, and complete at
20
the time of the Village's execution of this Agreement, and shall survive the
execution, delivery and acceptance hereof by the parties hereto and be in effect
throughout the Term of the Agreement.
9.03 NONIMPAIRMENT. Notwithstanding any other provision to the contrary
herein, in the TIF Ordinances, the Indenture, the Pledge Agreement, the Escrow
Agreement or the TIF Notes, and subject only to the rights of the Village under
the Pledge Agreement with respect to the Pledged Subordinated Interest, the
Village pledges to and agrees with beneficial owners of the TIF Notes and any
other obligations issued to evidence an indirect or direct interest in the TIF
Notes (collectively, the "Noteholders") that the Village will not limit or alter
the rights and powers vested in the Escrow Agent to receive and apply the
Incremental Taxes to the credit of the Developers Cost Account for the purpose
of paying principal and interest on the TIF Notes or otherwise so as to impair
the terms of the TIF Notes, the Indenture or the TIF Ordinances or in any way
impair the rights and remedies of the Noteholders until (a) the date on which
all of the TIF Notes or other obligations, together with interest thereon,
interest on any unpaid installments of interest, and all costs and expenses in
connection with any action or proceedings by or on behalf of the Noteholders are
fully met and discharged or (b), if later, the date on which the collection and
allocation of Incremental Taxes is no longer permitted under the Act (subject to
the rights of CenterPoint under Section 9.07 hereof). In addition, the Village
pledges to and agrees with the Noteholders and the Developer that the Village
will not limit or alter the basis on which Incremental Taxes are to be
collected, deposited or applied pursuant to the TIF Ordinances, the Indenture
and the Escrow Agreement so as to impair in any manner the terms of any such
contracts.
9.04 SUBORDINATION. The Village hereby acknowledges and agrees that the
rights and interests of the Trustee, the Escrow Agent and the Noteholders in and
to Incremental Taxes and other amounts pledged or intended to be applied to the
payment of the TIF Notes herein or under the Indenture are in each and every
respect prior to the rights and interests of the Village in and under the Pledge
Agreement and the Village hereby agrees that it shall execute and deliver a
subordination agreement in form and substance satisfactory to the Trustee, the
Escrow Agent, the Developer and any representative of the Noteholders to
evidence the foregoing. In furtherance of the foregoing, the Trustee, the Escrow
Agent and, to the extent provided in the Indenture, the Noteholders shall be
deemed to be third party beneficiaries hereunder, under the Escrow Agreement and
each related document, agreement and other instrument, and shall be entitled to
enforce their respective rights hereunder or thereunder.
9.05 FUTURE REVENUE BONDS.
(a) The Village agrees that at the request of Developer and upon the
filing of a Needs Certificate with the Village, the Village shall authorize,
issue and sell either:
(1) to a purchaser selected by the Village within sixty (60)
days of the filing of a Needs Certificate, or
(2) upon expiration of the period described in (a) or sooner
upon the election of the Village, to Developer or any affiliate
thereof, Future Revenue Bonds (as defined in the Revenue Note
Ordinance) in a principal amount not in excess of $10,000,000 plus the
21
Appropriation Shortfall (as defined in Section 15D of the Revenue
Note), maturing on August 1, 2020, subject to amortization or mandatory
sinking fund payments in amounts proportionate to the Mandatory Sinking
Fund Requirements (as defined in the Revenue Note Ordinance) relating
to the 2000 Revenue Notes, bearing interest at 10% per annum,
prepayable upon 30 days' prior notice at a price of par plus accrued
interest, and entitled to payment of principal and interest thereon out
of Net Revenues (as defined in the Revenue Note Ordinance) as described
in Section 12(C)(b), (d) and (e) of the Revenue Note Ordinance for the
purpose of financing additional capacity to the Village's Water and
Sewer System for users located in or connected to Deer Run Industrial
Park.
The Village acknowledges and agrees that such Future Revenue
Bonds are the Bonds described in Section 15(D) of the Revenue Note
Ordinance.
(b) Upon filing of a Needs Certificate with CenterPoint, but only upon
prior good faith efforts of the Village to use any or all of (a) the Expansion
Subaccount, the Expansion Capacity Fee or the right under other provisions of
Section 15 of the Revenue Note Ordinance to issue Future Additional Bonds, the
Village may issue Future Revenue Bonds under Section 15(D) of the Revenue Note
Ordinance to finance water or sewer services to users not located in the Deer
Run Industrial Park in a principal amount not in excess of the product of
$10,000,000 multiplied by a fraction (the numerator is the then capacity of the
System reserved for the Village pursuant to the Annexation Agreement and the
denominator of which is the then total capacity of the System). The Village
shall also have the right to issue Section 15D Bonds in principal amounts not
greater than the Appropriation Shortfall (as defined in the Revenue Note
Ordinance) for the purpose of financing the costs of the Base Water and Sewer
System, and Developer shall be obligated to purchase such Section 15D Bonds as
provided in Section 4.08 hereof.
9.06 FEASIBILITY CONSULTANTS. The Village hereby approves as
"Feasibility Consultants" the following organizations (a) Xxxxxxx & Xxxxxxxxx,
Inc. and (b) Real Estate Research Corporation.
9.07 AMENDMENT TO ACT. The Village and Developer hereby agree to seek
an amendment to the Act to provide for 23 full collection years for the
Incremental Taxes.
9.08 JOLIET TRAINING AREA. The Village shall, at no cost to the United
States Department of Army ("DOA"), provide to DOA (a) the right to tap on to the
Village's Combined Water and Sewer System for the Joliet Training Area and (b)
to the extent permitted by law, a limited amount of free service (the precise
amount of which will be determined at the discretion of the Village). The DOA
will be solely responsible for all cost of infrastructure for connection to the
System and any repair or maintenance related thereto.
22
SECTION 10. DEVELOPER'S EMPLOYMENT OBLIGATIONS
10.01 EMPLOYMENT OPPORTUNITY. The Developer, on behalf of itself and
its successors and assigns, hereby agrees, and shall contractually obligate its
or their various contractors, subcontractors or any Affiliate of the Developer
operating on the Property (collectively, with the Developer, the "Employers" and
individually an "Employer") to agree, that for the Term of this Agreement with
respect to Developer and during the period of any other party's provision of
services in connection with the construction of the TIF Funded Improvements or
occupation of the Property:
(a) Each Employer shall take affirmative action to ensure that
applicants are hired and employed without discrimination based upon race,
religion, color, sex, national origin or ancestry, age, handicap or disability,
sexual orientation, military discharge status, marital status, parental status
or source of income and are treated in a non-discriminatory manner with regard
to all job-related matters, including without limitation: employment, upgrading,
demotion or transfer; recruitment or recruitment advertising; layoff or
termination; rates of pay or other forms of compensation; and selection for
training, including apprenticeship. Each Employer agrees to post in conspicuous
places, available to employees and applicants for employment, notices setting
forth the provisions of this nondiscrimination clause. In addition, the
Employers, in all solicitations or advertisements for employees, shall state
that all qualified applicants shall receive consideration for employment without
discrimination based upon race, religion, color, sex, national origin or
ancestry, age, handicap or disability, sexual orientation, military discharge
status, marital status, parental status or source of income.
(b) Each Employer shall comply with all federal, state and local equal
employment and affirmative action statutes, rules and regulations, including but
not limited to the Illinois Human Rights Act, 775 ILCS 5/1-101 ET SEQ. (1993),
and any subsequent amendments and regulations promulgated thereto.
SECTION 11. ENVIRONMENTAL MATTERS
Pursuant to Section 42G of the Annexation Agreement, CenterPoint shall
assign to the Village, and the Village agrees to accept, the Memorandum of
Agreement between the Joliet Arsenal Development Authority, CenterPoint and
others in lieu of any further environmental indemnifications.
SECTION 12. ASSIGNMENT OF AGREEMENT/TRANSFER OF THE PROPERTY
12.01 ASSIGNMENT. The Developer may assign any of its right, title or
interest in or to this Agreement so long as one of the following sets of
conditions is satisfied:
(a) The Developer shall remain obligated with respect to the Phase
I Commitments, or
(b) If the Phase I Commitments have been satisfied and the
Developer pays or provides adequate assurances for payment of
the net present value, computed as of the effective date of
the assignment at a ten percent (10%) per annum discount rate,
of
23
the remaining payments of Increment to the Village in an
amount equal to the Village Annual Limit through the end of
the term of the Economic Development Project Area. In
exchange for any such payment, the Developer (or its
assignee) shall be entitled to receive any such prepaid
Increment as and when available; or
(c) The assignment is to an assignee which is a Qualified Person.
The Village shall have the option to waive some or all of the
requirements in (A) or (B).
12.02 TRANSFER OF PROPERTY. The rights of CenterPoint to lease,
mortgage, convey or otherwise transfer all or any part of the Project shall not
be restricted in any manner.
SECTION 13. INDEMNIFICATION
The Developer agrees to indemnify, defend and hold the Village harmless
from and against any losses, costs, damages, liabilities, claims, suits,
actions, causes of action and expenses (including, without limitation,
reasonable attorneys' fees and court costs) suffered or incurred by the Village
arising from or in connection with (i) the Developer's failure to comply with
any of the terms, covenants and conditions contained within this Agreement, or
(ii) the Developer's or any contractor's failure to pay General Contractors,
subcontractors or materialmen in connection with the TIF Funded Improvements or
any other Project improvement, or (iii) the existence of any material
misrepresentation or omission in this Agreement or the Economic Development Plan
that is the result of information supplied or omitted by the Developer or its
agents, employees, contractors or persons acting under the control or at the
request of the Developer or (iv) the Developer's failure to cure any
misrepresentation by the Developer in this Agreement.
SECTION 14. MAINTAINING RECORDS/RIGHT TO INSPECT
14.01 BOOKS AND RECORDS. The Developer shall keep and maintain
separate, complete, accurate and detailed books and records necessary to reflect
and fully disclose the total actual cost of the TIF Funded Improvements and the
disposition of all funds from whatever source allocated thereto, and to monitor
the TIF Funded Improvements. All such books, records and other documents,
including but not limited to the Developer's loan statements, General
Contractors' and contractors' sworn statements, general contracts, subcontracts,
purchase orders, waivers of lien, paid receipts and invoices, shall be available
at the Developer's offices for inspection, copying, audit and examination by an
authorized representative of the Village, at the Developer's expense. The
Developer shall incorporate this right to inspect, copy, audit and examine all
books and records into all contracts entered into by the Developer with respect
to the TIF Funded Improvements.
14.02 INSPECTION RIGHTS. Upon three (3) business days' notice, any
authorized representative of the Village shall have access to all portions of
the TIF Funded Improvements and the Property during normal business hours for
the Term of the Agreement for the purpose of determining compliance with this
Agreement.
24
SECTION 15. DEFAULT AND REMEDIES
15.01 EVENTS OF DEFAULT. The occurrence of any one or more of the
following events, subject to the provisions of SECTION 15.03, shall constitute
an "Event of Default" by the Developer hereunder:
(a) the failure by the Developer to deliver a signed lease with the
Railroad Company by December 31, 2000 for approximately 500 acres of intermodal
improvements in the Project; or
(b) the material failure of the Developer to fulfill its Phase I
Commitments (i) for 30 days after written notice from Village (which written
notice shall specify the nature of the failure and the steps which are required
to fulfill such Phase I Commitments), in the case of any failure which can be
cured by the payment of a sum of money, or (ii) for ninety (90) days after
written notice from Village in the case of any other failure; PROVIDED, HOWEVER,
that if such nonmonetary failure is susceptible of cure but cannot reasonably be
cured within such 90-day period and PROVIDED FURTHER that Developer shall have
commenced to cure such failure within such 90-day period and thereafter
diligently and expeditiously proceeds to cure the same, such 90-day period shall
be extended for an additional period of time as is reasonably necessary for
Developer in the exercise of due diligence to cure such failure, but the
aggregate additional cure period under this SUBPARAGRAPH (b) shall not exceed an
additional one hundred and twenty (120) days; or
(c) the failure of CenterPoint Properties Trust to execute and deliver
the CenterPoint Support Agreement; or
(d) the failure of the Developer to perform, keep or observe any of the
material covenants, conditions, promises, agreements or obligations of the
Developer under this Agreement or the Annexation Agreement (other than (a) - (c)
above); or
(e) the making or furnishing by the Developer to the Village of any
material representation, warranty, certificate, schedule, report or other
communication within or in connection with this Agreement or any related
agreement which is untrue or misleading in any material respect.
15.02 REMEDIES.
(a) Upon the occurrence and during the continuation of an Event of
Default listed in (a), (b) or (c) of SECTION 15.01 hereof and following
reasonable notice and opportunity to cure (herein, a "Material Breach"), the
Village shall have the right, in addition to all other remedies described in (b)
below, (i) to suspend the Developer's right to receive payments not yet funded
with respect to Project Reimbursement Requests or to increase the original
principal amount of the TIF Notes pursuant to a newly submitted Note Requisition
Request under this Agreement, (ii) to suspend the Developer's right to amounts
otherwise payable from the Developer Subaccount of the Accelerated Increment
Account and (iii) to require any amounts paid on the Pledged Subordinated
Interest either to be placed in escrow or to be applied in accordance with the
terms of the Pledge Agreement to cure any monetary damages of the Village
resulting from such Event of Default; PROVIDED, HOWEVER, no
25
right of the Village under this Agreement shall be exercisable in any manner
which would or may have an adverse effect on the security of any Noteholder, the
Escrow Agent or the Trustee.
(b) Following notice to the Developer and after a reasonable cure
period as provided in SECTION 15.03 hereof, upon the occurrence and during the
continuation of any Event of Default, the Village shall also have the following
remedies:
(1) suspend the right of the Developer to request or receive
disbursements of Incremental Taxes pursuant to a Note Requisition Request under
SECTION 4.02(b) hereof;
(2) suspend the right of the Developer to request or receive
an advance pursuant to a Project Reimbursement Request under SECTION 4.02(c)
hereof; or
(3) subject to SECTION 9.03 hereof pursue and secure any
available remedy for the observance and performance of the Developer's
obligations under this Agreement or to obtain damages for any breach thereof,
including but not limited to drawing on any letter of credit provided by the
Developer, injunctive relief or to the specific performance of such agreements
in any court of competent jurisdiction by any action or proceeding at law or in
equity.
15.03 CURATIVE PERIOD. In the event the Developer shall fail to perform
a covenant which the Developer is required to perform under this Agreement,
notwithstanding any other provision of this Agreement to the contrary, an Event
of Default shall not be deemed to have occurred unless the Developer shall have
failed to cure such default within ninety (90) days of its receipt of a written
notice from the Village specifying the nature of the default; PROVIDED, HOWEVER,
with respect to those defaults which are not capable of being cured within such
ninety (90) day period, the Developer shall not be deemed to have committed an
Event of Default under this Agreement if it has commenced to cure the alleged
default within such ninety (90) day period and thereafter diligently and
continuously prosecutes the cure of such default until the same has been cured.
15.04 TERMINATION OF PROCEEDINGS. In case the Village or Developer
shall have proceeded to enforce any right under this Agreement, and such
proceeding or other action shall have been discontinued or abandoned for any
reason (including a determination that no Event of Default has occurred and
continues to exist), or such proceeding or other action shall have been
determined adversely, then and in every such case the Village and the Developer
shall be restored to their former positions and rights hereunder, respectively,
with regard to the property or rights subject to this Agreement, and all rights,
remedies and powers of the parties hereto shall continue as if no such
proceedings had been taken.
SECTION 16. NOTICE
Unless otherwise specified, any notice, demand or request required
hereunder shall be given in writing at the addresses set forth below, by any of
the following means: (a) personal service; (b) telecopy or facsimile; (c)
overnight courier; or (d) registered or certified mail, return receipt
requested.
26
If to the Village: Xxxxxxxxx Xxxxx X. Xxxxxxxx
Village President
Village of Xxxxxx
000 Xxxx Xxxxxxxxxxx Xxxx
X.X. Xxx 000
Xxxxxx, Xxxxxxxx 00000
with copies to: Xxxxxxxx Xxxxxxxx
Village Clerk
Village of Xxxxxx
000 Xxxx Xxxxxxxxxxx Xxxx
X.X. Xxx 000
Xxxxxx, Xxxxxxxx 00000
Xxxxxx X. Xxxxxx, Esq.
Law Offices of Xxxxxx X. Xxxxxx, Ltd.
0000 Xxxxx Xxxxxxxxxx Xxxxxx
Xxxxxxxxxx, Xxxxxxxx 00000
Xxxxx X. Xxxxxxxxx
Xxxxxxx, Xxxxxxxxx & Cross, Ltd.
0000 Xxxxx Xxxx
Xxxxx 000
Xxxxxx, Xxxxxxxx 00000
If to the Developer: CenterPoint Properties Trust
c/o Xxxx Xxxxxx, Esq.
0000 Xxxxx Xxxxx
Xxxxxxxx, Xxxxxxxx 00000-0000
with copies to: Xxxxx X. Bonjour, Esq.
and Xxxxxxx X. Xxxxxx
Altheimer & Xxxx
00 Xxxxx Xxxxxx Xxxxx
Xxxxx 0000
Xxxxxxx, Xxxxxxxx 00000
Xxxxx X. Xxxxxxx, Esq.
Xxxx, Xxxxxxx & Xxxxxxxx
000 Xxxx Xxxxxx Xxxxx
Xxxxx 0000
Xxxxxxx, Xxxxxxxx 00000
27
Copies of all notices hereunder shall be sent to the Escrow Agent and the
Trustee and any notice asserting that an Event of Default has occurred shall be
sent to DCCA at the following addresses, or such revised address as any such
party shall give in writing to all other notice parties herein:
If to the Escrow
Agent or the Trustee: Bank One, National Association
0 Xxxx Xxx Xxxxx, Xxxxx XX0-0000
Xxxxxxx, Xxxxxxxx
Attention: Global Corporate Trust Services
If to DCCA: Illinois Department of Commerce and
Community Affairs
000 Xxxx Xxxxx Xxxxxx
Xxxxxxxxxxx, Xxxxxxxx 00000-0000
Attention: Director
and
Illinois Department of Commerce
and Community Affairs
000 Xxxx Xxxxxxxx Xxxxxx
Xxxxx 0-000
Xxxxxxx, Xxxxxxxx 00000
Attention: General Counsel
with a copy to: Xxxxxxx & Xxxxxxxx Ltd.
000 Xxxxx Xxxxxxxx Xxxxxx
Xxxxx 0000
Xxxxxxx, Xxxxxxxx 00000
Attention: Xxxxxx X. Xxxxx, Esq.
Such addresses may be changed by notice to the other parties given in
the same manner provided above. Any notice, demand, or request sent pursuant to
either clause (a) or (b) hereof shall be deemed received upon such personal
service or upon dispatch. Any notice, demand or request sent pursuant to clause
(c) shall be deemed received on the day immediately following deposit with the
overnight courier and any notices, demands or requests sent pursuant to
subsection (d) shall be deemed received two (2) business days following deposit
in the mail.
SECTION 17. MISCELLANEOUS
17.01 AMENDMENT. This Agreement and the Exhibits attached hereto may
not be amended without the prior written consent of the Village and the
Developer.
17.02 ENTIRE AGREEMENT. This Agreement (including each Exhibit attached
hereto, which is hereby incorporated herein by reference) and the documents,
agreements and other instruments
28
to which reference is made herein or therein constitute the entire agreements
between the parties hereto and it supersedes all prior agreements, negotiations
and discussions between the parties relative to the subject matter hereof.
17.03 LIMITATION OF LIABILITY. No member, official or employee of the
Village shall be personally liable to the Developer or any successor in interest
in the event of any default or breach by the Village or for any amount which may
become due to the Developer from the Village or any successor in interest or on
any obligation under the terms of this Agreement.
17.04 FURTHER ASSURANCES. The Developer agrees to take certain actions,
including the execution and delivery of such documents, instruments, petitions
and certifications as may become necessary or appropriate to carry out the
terms, provisions and intent of this Agreement.
17.05 WAIVER. Waiver by the Village or the Developer with respect to
any breach of this Agreement shall not be considered or treated as a waiver of
the rights of the respective party with respect to any other default or with
respect to any particular default, except to the extent specifically waived by
the Village or the Developer in writing.
17.06 ENFORCEABILITY OF THE AGREEMENT; REMEDIES.
(a) This Agreement shall be enforceable in any court of competent
jurisdiction by any of the parties by an appropriate action at law or in equity
to secure the performance of the provisions and covenants herein described.
(b) Any violation of this Agreement by the Village shall entitle the
Developer to the remedy of specific performance, and/or any other remedy
available at law or in equity.
(c) No action based upon any violation of this Agreement shall be
brought except until after written notice to the breaching party describing the
nature of the alleged violation, and until said party shall have had a thirty
(30) day period in which to cure the violation unless a different time period is
provided in this Agreement.
(d) All remedies provided for in this Agreement are cumulative and the
election or use of any particular remedy by any of the parties hereto shall not
preclude that party from pursuing such other or additional remedies or such
other or additional relief as it may be entitled to either in law or in equity.
(e) In the event any action is brought arising from a breach of this
Agreement, or to enforce any provision of this Agreement, the prevailing party
shall be entitled to recover its costs expenses and reasonable attorneys' fees
form the breaching party.
17.07 DISCLAIMER. Nothing contained in this Agreement nor any act of
the Village shall be deemed or construed by any of the parties, or by any third
person, to create or imply any relationship of third-party beneficiary,
principal or agent, limited or general partnership or joint venture, or to
create or imply any association or relationship involving the Village.
29
17.08 HEADINGS. The paragraph and section headings contained herein are
for convenience only and are not intended to limit, vary, define or expand the
content thereof.
17.09 COUNTERPARTS. This Agreement may be executed in several
counterparts, each of which shall be deemed an original and all of which shall
constitute one and the same agreement.
17.10 SEVERABILITY. If any provision in this Agreement, or any
paragraph, sentence, clause, phrase, word or the application thereof, in any
circumstance, is held invalid, this Agreement shall be construed as if such
invalid part were never included herein and the remainder of this Agreement
shall be and remain valid and enforceable to the fullest extent permitted by
law.
17.11 CONFLICT. In the event of a conflict between any provisions of
this Agreement and the provisions of the TIF Ordinances and/or the TIF Note
Ordinance, if any, such ordinance(s) shall prevail and control.
17.12 GOVERNING LAW. This Agreement shall be governed by and construed
in accordance with the internal laws of the State of Illinois, without regard to
its conflicts of law principles.
17.13 FORM OF DOCUMENTS. All documents required by this Agreement to be
submitted, delivered or furnished to the Village shall be in form and content
satisfactory to the Village.
17.14 TERMINATION. CenterPoint shall have the right to terminate this
Agreement at any time prior to the first anniversary of the date hereof if, in
CenterPoint's sole discretion, litigation shall be pending in, or judgment
entered by, a court of competent jurisdiction relative to the alleged invalidity
of the Economic Development Project Area, this Agreement, or the TIF Ordinances,
in which event all further financial obligations of CenterPoint shall cease
except as to funds irrevocably committed as provided in Section 49 of the
Annexation Agreement.
17.15 BINDING EFFECT. This Agreement shall be binding upon the
Developer, the Village and their respective successors and permitted assigns (as
provided herein) and shall inure to the benefit of the Developer, the Village
and their respective successors and permitted assigns (as provided herein).
17.16 FORCE MAJEURE. Neither the Village nor the Developer nor any
successor in interest to either of them shall be considered in breach of or in
default of its obligations under this Agreement in the event of any delay caused
by damage or destruction by fire or other casualty, strike, shortage of
material, unusually adverse weather conditions such as, by way of illustration
and not limitation, severe rain storms or below freezing temperatures of
abnormal degree or for an abnormal duration, tornadoes or cyclones, and other
events or conditions beyond the reasonable control of the party affected which
in fact interferes with the ability of such party to discharge its obligations
hereunder.
17.17 EXHIBITS. All of the exhibits attached hereto are incorporated
herein by reference.
30
31
IN WITNESS WHEREOF, the parties hereto have caused this Redevelopment
Agreement to be executed on or as of the day and year first above written.
ATTEST: VILLAGE OF XXXXXX, an Illinois home rule municipality
_________________________ By: ____________________________________
Xxxxxxxx Xxxxxxxx Xxxxx X. Xxxxxxxx
Village Clerk Village President
[SEAL]
ATTEST: CENTERPOINT INTERMODAL LLC,
an Illinois limited liability company
_________________________ By:_______________________________________
Xxxx X. Xxxxxx Xxxxxxx X. Xxxxxx
Secretary Manager
ATTEST: CENTERPOINT REALTY SERVICES, INC.
an Illinois corporation
_________________________ By:_______________________________________
Xxxx X. Xxxxxx Xxxxxxx X. Xxxxxx
Secretary President
32
STATE OF ILLINOIS )
) ss.
COUNTY OF DUPAGE )
ACKNOWLEDGMENT
I, the undersigned, a Notary Public, in and for the County and State aforesaid,
DO HEREBY CERTIFY that the above-named Xxxxxxx X. Xxxxxx and Xxxx X. Xxxxxx,
personally known to me to be one of the Managers and Secretary, respectively, of
CENTERPOINT INTERMODAL L.L.C., an Illinois limited liability company, personally
known to me to be the same persons whose names are subscribed to the foregoing
instrument, appeared before me this day in person and acknowledged that they
signed and delivered the said instrument as their free and voluntary act, and
the free and voluntary act of the said Trust, for the uses and purposes therein
set forth.
GIVEN under my hand and official seal, this 7th day of August, 2000.
------------------------------
Notary Public
33
STATE OF ILLINOIS )
) ss.
COUNTY OF DUPAGE )
ACKNOWLEDGMENT
I, the undersigned, a Notary Public, in and for the County and State aforesaid,
DO HEREBY CERTIFY that the above-named Xxxxxxx X. Xxxxxx and Xxxx X. Xxxxxx,
personally known to me to be the President and Secretary, respectively, of
CENTERPOINT REALTY SERVICES, INC., an Illinois corporation, personally known to
me to be the same persons whose names are subscribed to the foregoing
instrument, appeared before me this day in person and acknowledged that they
signed and delivered the said instrument as their free and voluntary act, and
the free and voluntary act of the said Trust, for the uses and purposes therein
set forth.
GIVEN under my hand and official seal, this 7th day of August, 2000.
------------------------------
Notary Public
34
STATE OF ILLINOIS )
) ss.
COUNTY OF WILL )
ACKNOWLEDGMENT
I, the undersigned, a Notary Public, in and for the County and State aforesaid,
DO HEREBY CERTIFY that XXXXX X. XXXXXXXX, personally known to me to be the
Village President of the VILLAGE OF XXXXXX, a municipal corporation, and
XXXXXXXX XXXXXXXX, personally known to me to be the Village Clerk of said
municipal corporation, and personally known to me to be the same persons whose
names are subscribed to the foregoing instrument, appeared before me this day in
person and severally acknowledged that as such Village President and Village
Clerk, they signed and delivered the said instrument and caused the corporate
seal of said municipal corporation to be affixed thereto, pursuant to authority
given by the Board of Trustees of said municipal corporation, as their free and
voluntary act, and as the free and voluntary act and deed of said municipal
corporation, for the uses and purposes therein set forth.
GIVEN under my hand and official seal, this 7th day of August, 2000.
---------------------------------------
Notary Public
35
EXHIBIT A
LEGAL DESCRIPTION
A - 1
EXHIBIT B
VILLAGE OF XXXXXX ECONOMIC DEVELOPMENT PROJECT AND PLAN
(DEER RUN INDUSTRIAL PARK ECONOMIC DEVELOPMENT PROJECT AREA)
B - 1
EXHIBIT C
BASE PROJECTED TAX INCREMENT
C - 1
EXHIBIT D
PROJECT BUDGET
D - 1
EXHIBIT E
PHASE I PUBLIC IMPROVEMENTS
E - 1
EXHIBIT F
ARSENAL SITE DRAWING
F - 1
EXHIBIT G
INFRASTRUCTURE IMPROVEMENTS FOR INTERMODAL FACILITIES
G - 1
EXHIBIT H-1
OPINION OF DEVELOPER'S COUNSEL
August __, 0000
Xxxxxxx xx Xxxxxx Xxxxxxxx Department of Commerce and
000 Xxxx Xxxxxxxxxxx Xxxx Xxxxxxxxx Xxxxxxx
X.X. Xxx 000 000 Xxxx Xxxxxxxx Xxxxxx
Xxxxxx, Xxxxxxxx 00000 Xxxxx 0-000
Xxxxxxx, XX 00000
RE: XXXX XXX XXXXXXXXXX XXXX, XXXXXX, XXXXXXXX (THE "PROJECT")
Ladies and Gentlemen:
We have served as counsel to CenterPoint Intermodal LLC, an Illinois
limited liability company (the "Developer") and CenterPoint Realty Services,
Inc., an Illinois corporation ("CRS"), in connection with (a) that certain
Redevelopment Agreement dated as of August 1, 2000 (the "Redevelopment
Agreement") among the Developer, CRS and the Village of Xxxxxx (the "Village"),
(b) that certain Deer Run Industrial Park Economic Development Area TIF Fund
Escrow Agreement dated as of August 1, 2000 (the "TIF Fund Escrow Agreement")
among Developer, CRS, the Village and Bank One, National Association, as Escrow
Agent, and (c) the provision of tax increment financing assistance to the
Developer and CRS from the Village relating to the redevelopment of certain land
and the construction of certain improvements thereon located in the Deer Run
Industrial Park Economic Development Project Area (the "Project"). We have also
served as special counsel to CenterPoint Properties Trust, a Maryland real
estate investment trust ("CNT") in connection with a certain Standby Purchase
Agreement dated as of August 1, 2000 (the "Standby Purchase Agreement'), between
CNT and the Illinois Department of Commerce and Community Affairs ("DCCA") and
accepted by the Village. Terms not defined herein shall have the meanings
assigned thereto in the Redevelopment Agreement.
In that capacity, we have examined, among other things, the following
agreements, instruments and documents of even date herewith, hereinafter
referred to as the "Documents":
(a) the Redevelopment Agreement;
(b) TIF Fund Escrow Agreement;
(c) the Annexation Agreement (as defined in the Redevelopment
Agreement); and
H - 1
(d) the Standby Purchase Agreement.
In rendering this opinion we have also examined the original or
certified, conformed or photostatic copies of: Developer's Operating Agreement
and Articles of Organization, CRS's Articles of Incorporation and By-Laws,
certificates of good standing for the Developer, CRS and CNT from the Illinois
Secretary of State, the Certifications (as defined below), and such other
documents and records pertaining to our clients as in our judgment are necessary
or appropriate to enable us to render the opinions expressed below.
For the purposes of this opinion, we have assumed that:
(a) The execution and delivery of all Documents and other documents
reviewed by us, and the entry into and performance of the transactions
contemplated by the Documents, by all parties other than Developer, CRS and CNT
(collectively, "CenterPoint") have been duly authorized by all necessary
actions; the Documents and other documents reviewed constitute the valid and
binding obligations of all parties other than CenterPoint.
(b) All natural persons who are signatories to the Documents were
legally competent at the time of execution; all signatures (other than those of
CenterPoint) on the Documents and other documents reviewed by us are genuine;
the copies of all documents submitted to us are accurate and complete and
conform to originals; all material terms and conditions of the relationship
between CenterPoint and the other parties to such agreements are correctly and
completely reflected in the Documents.
Based upon the foregoing, but subject to the assumptions,
qualifications and limitations set forth herein, we are of the opinion that:
1. The Developer is a limited liability company organized and validly
existing under the laws of Delaware and in good standing under the laws of the
State of Illinois, and has full power and authority to own and lease its
properties and to carry on its business as presently conducted. CRS is an
Illinois corporation duly organized, validly existing and in good standing under
the laws of the State of Illinois, and has full power and authority to own and
lease its properties and to carry on its business as presently conducted.
2. The Documents (a) have been properly authorized, executed and
delivered by or on behalf of the Developer, CRS and CNT, as applicable, (b)
constitute the legal, valid and binding obligations of the Developer, CRS and
CNT, as applicable, and (c) are enforceable against the Developer, CRS and CNT,
as applicable, in accordance with their respective terms.
3. No authorizations, approvals or consents of, or filings or
registrations with, or the giving of notice to, any governmental or regulatory
authority or agency of the State of Illinois or any political subdivision
thereof are necessary for the execution and delivery of the Documents by
CenterPoint or for the validity or enforceability thereof as against
CenterPoint, except for recording or filing of the Documents, as appropriate.
H - 2
4. To our knowledge, there are no judgments outstanding against the
Developer, CRS or CNT (relying solely on judgment searches of the Developer, CRS
and CNT performed by our Docket Department on July ___, 2000) and no legal or
administrative proceedings pending or threatened before any court or
governmental agency against the Developer, CRS or CNT.
5. To our knowledge relying solely on the certifications of the
Developer, CRS and CNT (attached hereto and made a part hereof, the
"Certifications") without further investigation, there is no default by the
Developer, CRS and CNT with respect to any indenture, loan agreement, mortgage,
deed of trust, note or any other agreement or instrument to which the Developer,
CRS or CNT is a party or by which the Developer, CRS or CNT is bound, a default
under which would have a material adverse effect on the Developer, CRS or CNT or
their businesses.
6. To our knowledge relying solely on the Certifications, without
further investigation, neither the Developer nor CRS nor CNT is in default with
respect to any order, writ, injunction or decree of any court, government or
regulatory authority or in default in or under any law, order, regulation or
demand of any governmental agency or instrumentality, a default under which
would have a material adverse effect on the Developer, CRS, CNT or their
respective business.
7. To our knowledge there is no litigation pending or, to the best of
our knowledge based solely on the Certifications, threatened against CenterPoint
in any court in any way challenging the existence of the Developer, CRS or CNT
or seeking to restrain or enjoin the execution and delivery of the Documents, or
in any way contesting or calling into question the validity or enforceability of
the Documents or the power and authority of the Developer, CRS or CNT with
respect thereto.
The opinions set forth above are subject to the following
qualifications:
(i) Wherever we indicate that our opinion with respect to the existence
or absence of facts is based on our knowledge, our opinion is based solely on
(1) the actual knowledge of the attorneys currently with the firm who have
represented CenterPoint in connection with the transactions contemplated by the
Documents and of any other attorneys presently in our firm whom we have
determined are likely, in the course of representing any of said parties, to
have knowledge of the matters covered by this opinion, (2) the representations
and warranties of said parties contained in the Documents, and (3) the
Certifications, and we have not undertaken any independent investigation (and we
have not caused to be made any review of any court file or indices except as
described in opinion 4 above) and no inference as to our knowledge should be
drawn from our representation of CenterPoint or otherwise. However, after having
reviewed with CenterPoint, we know of no facts which lead us to believe such
factual matters are untrue or inaccurate;
(ii) Your ability to enforce the Documents may be limited by applicable
bankruptcy, reorganization, insolvency, moratorium, fraudulent conveyance or
transfer and other similar laws now or hereafter in effect relating to or
affecting creditors' rights generally;
H - 3
(iii) Enforcement of your rights and remedies may be limited by general
principles of equity, regardless of whether such enforcement is considered in a
proceeding in equity or at law, and in this regard we have assumed that you will
exercise your rights and remedies under the Documents in good faith and in
circumstances and a manner which are commercially reasonable;
(iv) Certain provisions of the Documents may be rendered unenforceable
or limited by applicable laws and judicial decisions but such laws and judicial
decisions do not render the Documents invalid as a whole; and
(v) We express no opinion as to the enforceability of any provisions of
the Documents waiving the right to trial by jury.
Our opinion is limited to the laws of the United States (except as set
forth below) and the laws of the State of Illinois and political subdivisions
thereof (with respect to political subdivision, as to matters set forth in
Paragraph 3 only) in effect on the date hereof as they presently apply. We shall
have no continuing obligations to inform you of changes in law or fact
subsequent to the date hereof or of facts of which we become aware after the
date hereof.
We express no opinion as to matters of title or priority or perfection
of liens or security interests with regard to real and personal property. We
understand that, with respect to all real and personal property security
interests intended to be created by the Documents and the priority of the liens
thereof, you will rely on a title insurance policy and such Uniform Commercial
Code and other searches as you deem adequate, and, accordingly, we express no
opinion to such matters.
We have not reviewed and do not opine as to: (i) compliance by the
Project with applicable zoning, health, safety, building, environmental, land
use or subdivision laws, ordinances, codes, rules or regulations, (ii) ERISA
laws, rules and regulations, or (iii) Federal or state taxation, banking,
securities or "blue sky" laws, rules or regulations.
This opinion is limited to the matters set forth herein. No opinion may
be inferred or implied beyond the matters expressly contained herein. This
opinion is rendered solely for your benefit and no other person or entity shall
be entitled to rely on any matter set forth herein without the express written
consent of the undersigned.
Very truly yours,
X - 0
XXXXXXX X-0
XXXXXXX XX XXXXXXX COUNSEL
August __, 2000
Illinois Department of Commerce and CenterPoint Properties Trust
Community Affairs CenterPoint Intermodal, LLC
000 Xxxx Xxxxxxxx Xxxxxx XxxxxxXxxxx Realty Services, Inc.
Xxxxx 0-000 x/x XxxxxxXxxxx Xxxxxxxxxx Xxxxx
Xxxxxxx, XX 00000 0000 Xxxxx Xxxx
Xxx Xxxxx, XX 00000-0000
RE: XXXX XXX XXXXXXXXXX XXXX, XXXXXX, XXXXXXXX (THE "PROJECT")
Ladies and Gentlemen:
We have served as counsel to the Village of Xxxxxx, Illinois (the
"Village") in connection with (a) the adoption of proceedings (the "Annexation
Proceedings") by the President and the Board of the Village preliminary to and
authorizing the annexation of the property described on Exhibit A pursuant to
that certain Annexation Agreement dated June __, 2000 (the "Annexation
Agreement") among the Village, CenterPoint Realty Services, Inc. ("CRS"),
CenterPoint Intermodal, LLC (the "Developer"), and CenterPoint Properties Trust,
a Maryland real estate investment trust ("CNT"), (b) that certain Redevelopment
Agreement dated as of August 1, 2000 (the "Redevelopment Agreement") among the
Developer, CRS and the Village, (c) that certain Deer Run Industrial Park
Economic Development Area TIF Fund Escrow Agreement dated as of August 1, 2000
(the "TIF Fund Escrow Agreement") among Developer, CRS, the Village and Bank
One, National Association, as Escrow Agent, (d) two separate Revenue Obligation
Loan Agreements, each dated as of August 1, 2000 (collectively, the "DCCA Loan
Agreement") between the Village and the Illinois Department of Commerce and
Community Affairs ("DCCA"), (e) an Ordinance adopted on August 7, 2000 (the
"Note Ordinance") authorizing the issuance of the Notes (as defined in the DCCA
Loan Agreement) and authorizing the execution and delivery of the DCCA Loan
Agreement, and (f) the provision of tax increment financing assistance to the
Developer and CRS from the Village relating to the redevelopment of certain land
and the construction of certain improvements thereon located in the Deer Run
Industrial Park Economic Development Project Area (the "Project"). Terms not
defined herein shall have the meanings assigned thereto in the Redevelopment
Agreement.
In that capacity, we have examined, among other things, the following
agreements, instruments and documents of even date herewith, hereinafter
referred to as the "Documents":
H - 5
(a) the Redevelopment Agreement;
(b) TIF Fund Escrow Agreement;
(c) the Annexation Agreement;
(d) the Standby Purchase Agreement dated as of August 1, 2000
between CNT and DCCA, accepted by the Village (the "Support
Agreement");
(e) the DCCA Loan Agreement; and
(f) the Notes (as defined in the DCCA Loan Agreement).
We have also reviewed a certified copy of the Note Ordinance and the Annexation
Proceedings.
For the purposes of this opinion, we have assumed that:
(a) The execution and delivery of all Documents and other documents
reviewed by us, and the entry into and performance of the transactions
contemplated by the Documents, by all parties other than the Village have been
duly authorized by all necessary actions; the Documents and other documents
reviewed constitute the valid and binding obligations of all parties other than
the Village.
(b) All natural persons who are signatories to the Documents were
legally competent at the time of execution; all signatures (other than those of
the Village) on the Documents and other documents reviewed by us are genuine;
the copies of all documents submitted to us are accurate and complete and
conform to originals; all material terms and conditions of the relationship
between the Village and the other parties to such agreements are correctly and
completely reflected in the Documents.
Based upon the foregoing, but subject to the assumptions,
qualifications and limitations set forth herein, we are of the opinion that:
1. The Village is an Illinois home rule unit organized and existing
under the laws and constitution of the State of Illinois.
2. The Village has the power and authority under the laws of the State
of Illinois to adopt the Annexation Proceedings and the Note Ordinance, to enter
into the Documents, to issue, sell and deliver the Notes pursuant thereto, and
to pledge the Revenues under the Note Ordinance and DCCA Loan Agreement. The
Annexation Proceedings and Note Ordinance have been duly adopted and are valid
and in full force and effect and are lawful authority for the execution,
delivery and performance of the Documents.
3. The Documents (a) have been properly authorized, executed and
delivered by or on behalf of the Village, (b) constitute the legal, valid and
binding obligations of the Village, and (c) are enforceable against the Village,
in accordance with their respective terms.
H - 6
4. No authorizations, approvals or consents of, or filings or
registrations with, or the giving of notice to, any governmental or regulatory
authority or agency of the State of Illinois or any political subdivision
thereof are necessary for the execution and delivery of the Documents by the
Village or for the validity or enforceability thereof as against the Village
except for recording or filing of the Documents, as appropriate.
5. To our knowledge, there are no judgments outstanding against the
Village (relying solely on judgment searches with respect to the Village
performed on July ___, 2000) and no legal or administrative proceedings pending
or threatened in writing before any court or governmental agency against the
Village.
6. To our knowledge relying solely on the certifications of the Village
(attached hereto and made a part hereof, the "Certifications") without further
investigation, there is no default by the Village with respect to any indenture,
loan agreement, mortgage, deed of trust, note or any other agreement or
instrument to which the Village is a party or by which the Village is bound, a
default under which would have a material adverse effect on the Village.
7. To our knowledge relying solely on the Certifications, without
further investigation, the Village is not in default with respect to any order,
writ, injunction or decree of any court, government or regulatory authority or
in default in or under any law, order, regulation or demand of any governmental
agency or instrumentality, a default under which would have a material adverse
effect on the Village or its System (as defined in the DCCA Loan Agreement).
8. To our knowledge there is no litigation pending or, to the best of
our knowledge based solely on the Certifications, threatened against the Village
in any court in any way challenging the existence of the Village or seeking to
restrain or enjoin the execution and delivery of the Documents, or in any way
contesting or calling into question the validity or enforceability of the
Documents or the power and authority of the Village with respect thereto.
The opinions set forth above are subject to the following
qualifications:
(i) Wherever we indicate that our opinion with respect to the existence
or absence of facts is based on our knowledge, our opinion is based solely on
(1) the actual knowledge of the attorneys currently with the firm who have
represented the Village in connection with the transactions contemplated by the
Documents and of any other attorneys presently in our firm whom we have
determined are likely, in the course of representing any of said parties, to
have knowledge of the matters covered by this opinion, (2) the representations
and warranties of said parties contained in the Documents, and (3) the
Certifications, and we have not undertaken any independent investigation (and we
have not caused to be made any review of any court file or indices except as
described in opinion 4 above) and no inference as to our knowledge should be
drawn from our representation of the Village or otherwise. However, after having
reviewed with the Village, we know of no facts which lead us to believe such
factual matters are untrue or inaccurate;
H - 7
(ii) Your ability to enforce the Documents and Note Ordinance may be
limited by applicable bankruptcy, reorganization, insolvency, moratorium,
fraudulent conveyance or transfer and other similar laws now or hereafter in
effect relating to or affecting creditors' rights generally;
(iii) Enforcement of your rights and remedies may be limited by general
principles of equity, regardless of whether such enforcement is considered in a
proceeding in equity or at law, and in this regard we have assumed that you will
exercise your rights and remedies under the Documents and Note Ordinance in good
faith and in circumstances and a manner which are commercially reasonable;
(iv) Certain provisions of the Documents and Note Ordinance may be
rendered unenforceable or limited by applicable laws and judicial decisions may
not render the document invalid as a whole but such laws and judicial decisions
do not render the Documents invalid as a whole; and
(v) We express no opinion as to the enforceability of any provisions of
the Documents waiving the right to trial by jury.
Our opinion is limited to the laws of the United States (except as set
forth below) and the laws of the State of Illinois and political subdivisions
thereof (with respect to political subdivision, as to matters set forth in
Paragraph 4 only) in effect on the date hereof as they presently apply. We shall
have no continuing obligations to inform you of changes in law or fact
subsequent to the date hereof or of facts of which we become aware after the
date hereof.
We express no opinion as to matters of title or priority or perfection
of liens or security interests with regard to real and personal property. We
understand that, with respect to all real and personal property security
interests intended to be created by the Documents and the priority of the liens
thereof, you will rely on a title insurance policy and such Uniform Commercial
Code and other searches as you deem adequate, and, accordingly, we express no
opinion to such matters.
We have not reviewed and do not opine as to: (i) compliance by the
Project with applicable zoning, health, safety, building, environmental, land
use or subdivision laws, ordinances, codes, rules or regulations, (ii) ERISA
laws, rules and regulations, or (iii) Federal or state taxation, banking,
securities or "blue sky" laws, rules or regulations.
This opinion is limited to the matters set forth herein. No opinion may
be inferred or implied beyond the matters expressly contained herein. This
opinion is rendered solely for your benefit and no other person or entity shall
be entitled to rely on any matter set forth herein without the express written
consent of the undersigned.
Very truly yours,
H - 8
EXHIBIT I
REQUISITION CERTIFICATE
NOTE REQUISITION REQUEST FORM
State of Illinois )
) ss.
County of Xxxx )
The affiant, _______________, ____________ of CenterPoint Intermodal
LLC, an Illinois limited liability company (the "Developer"), being duly
sworn on oath deposes and says pursuant to that certain Redevelopment
Agreement dated as of August 1, 2000 (the "Redevelopment Agreement") between
the Developer and the Village of Xxxxxx, Will County, Illinois (the
"Village") and that certain Indenture of Trust dated as of ____________, 2000
(the "Indenture") between the Village and BANK ONE, NATIONAL ASSOCIATION, as
trustee (the "Trustee"), receiving the Tax Increment Allocation Notes, Series
0000X (Xxxx Xxx Xxxxxxxxxx Xxxx Project) (the "Series 2000A Notes"), of the
Village, as follows:
A. This Paragraph A sets forth and is a true and complete statement of
all expenditures for the TIF Project (as defined in the Indenture) to date:
Description Amount
----------- ------
Total $______________
B. The work paid for by the expenditures described in Paragraph A has
been completed.
C. This Paragraph C sets forth and is a true and complete statement of
the aggregate amount paid by the Village to the Developer to date as
reimbursement for TIF Funded Improvements paid by the Developer or any Affiliate
for the TIF Project:
Original Principal Amount of Series 2000A Notes $______________
Project Reimbursement Requests ______________
Options Rights Requests ______________
Total $______________
I - 1
D. The Developer requests reimbursement for the following TIF Project
Costs:
Description Amount
----------- ------
$______________
E. None of the TIF Funded Improvements referenced in Paragraph D above
have been previously reimbursed by the Village.
F. The total amount referenced in Paragraph D above represents the
actual amount payable to (or paid to) the general contractor and/or
subcontractors who have performed work on the TIF Project, and/or their payees.
G. The Developer has approved all work and materials for the amount
referenced in Paragraph D above, and such work and materials conform to the
Plans and Specifications (as defined in the Redevelopment Agreement) as such may
be amended if request is in connection with the TIF Project.
H. This Paragraph H sets forth and is a true and complete statement of
all expenditures for the Water and Sewer Project (as defined on the Indenture)
for which the Developer has been reimbursed to date:
Description Amount
----------- ------
$------------------
$------------------
Total
I. The Developer requests reimbursement for the following Water and
Sewer Project Costs:
Description Amount
----------- ------
$------------------
$------------------
Total
J. None of the Water and Sewer Project Costs referenced in Paragraph I
above have been previously reimbursed by the Village.
I - 2
K. This Paragraph K is a true and complete statement of all
expenditures for the Road Project (as defined in the Indenture) for which the
Developer has been reimbursed to date:
Description Amount
----------- ------
$------------------
$------------------
Total
L. The Developer requests reimbursement for the following Road Project
Costs:
Description Amount
----------- ------
$------------------
$------------------
M. None of the Road Project Costs referenced in Paragraph L above have
been previously reimbursed by the Village.
N. As provided in the Redevelopment Agreement, by virtue of the payment
or incurrence of the reimbursable costs described in Paragraphs D, I and L, the
Developer shall be deemed to have purchased a Series 2000A Note in an Original
Principal Amount equal to such costs and the Trustee is therefore hereby
requested to authenticate and deliver a Series 2000A Note in the Original
Principal Amount of $____________ in the form provided in the Indenture with
such terms as provided for in the Indenture, including an Interest Commencement
Date, Tender Periods and prices, and a mandatory sinking fund schedule
determined by the Calculation Agent as provided in the Indenture.
O. The representations and warranties of the Developer contained in the
Redevelopment Agreement are true and correct in each material respect and the
Developer is in compliance with all material covenants and contained therein.
P. No Event of Default under the Redevelopment Agreement exists.
Q. The undersigned is an Authorized Developer Representative (as
defined in the Indenture).
R. [The most recent Revenue Projection Certificate (as defined in the
Indenture) was dated ___________ and a copy thereof is attached hereto.]
[Attached hereto is an updated Revenue Projection Certificate dated __________,
____ together with evidence that such certificate has been verified by the
Feasibility Consultant as provided in the Redevelopment Agreement.
S. Attached hereto is the Calculation Agent's Report as required by the
Indenture.
I - 3
All capitalized terms which are not defined herein have the meanings
given such terms in the Indenture.
CENTERPOINT INTERMODAL LLC,
an Illinois limited liability company
By: _________________________________
Name: ________________________
Title: ________________________
Subscribed and sworn before me this
_________ day of _________ , 2000.
_____________________________________
Notary Public
My commission expires: ________________
ACCEPTED:
BANK ONE, NATIONAL ASSOCIATION,
as Trustee,
By: _________________________________
Name: ________________________
Title: ________________________
cc: Village of Xxxxxx
I - 4
EXHIBIT J
REQUISITION CERTIFICATE
PROJECT REIMBURSEMENT REQUEST FORM
State of Illinois )
) ss.
County of Xxxx )
The affiant, _______________, _____________ of CenterPoint
Intermodal LLC, an Illinois limited liability company (the "Developer"),
being duly sworn on oath deposes and says pursuant to that certain
Redevelopment Agreement dated as of August 1, 2000 (the "Redevelopment
Agreement") between the Developer and the Village of Xxxxxx, Will County,
Illinois (the "Village") and that certain Escrow Agreement dated as of
____________, 2000 (the "Escrow Agreement") among the Village, BANK ONE,
NATIONAL ASSOCIATION, as escrow agent (the "Escrow Agent"), the Developer and
CenterPoint Realty Services, a ___________________ ("Realty"), as follows:
A. This Paragraph A sets forth and is a true and complete statement of
all expenditures for the TIF Project (as defined in the Indenture) to date:
Amount
------
Total $______________
B. The work paid for by the expenditures described in Paragraph A has
been completed.
C. This Paragraph C sets forth and is a true and complete statement of
the aggregate amount paid by the Village to the Developer to date as
reimbursement for TIF Funded Improvements paid by the Developer or any Affiliate
for the TIF Project:
Original Principal Amount of Series 2000A Notes $______________
Project Reimbursement Requests ______________
Option Rights Requests ______________
Total $______________
D. The Developer requests reimbursement for the following TIF Funded
Improvements amount in the form of a cash reimbursement:
$______________
E. None of the TIF Funded Improvements referenced in Paragraph D above
have been previously reimbursed by the Village.
J - 1
F. The total amount referenced in Paragraph D above represents the
actual amount payable to (or paid to) the general contractor and/or
subcontractors who have performed work on the TIF Project, and/or their payees.
G. The Developer has approved all work and materials for the amount
referenced in Paragraph D above, and such work and materials conform to the
Plans and Specifications (as defined in the Redevelopment Agreement) as such may
be amended if request is in connection with the TIF Project.
H. The representations and warranties contained in the Redevelopment
Agreement are true and correct in each material respect and the Developer is in
compliance with all material covenants and contained therein.
I. No Event of Default under the Redevelopment Agreement exists.
J. The undersigned is an Authorized Developer Representative
(as defined in the Indenture).
All capitalized terms which are not defined herein have the meanings
given such terms in the Escrow Agreement.
Dated: _________, 200_.
CENTERPOINT INTERMODAL LLC,
an Illinois limited liability company
By: _________________________________
Name: ________________________
Title: ________________________
Subscribed and sworn before me this
_________ day of _________ , 2000.
_____________________________________
Notary Public
My commission expires: ________________
ACCEPTED:
BANK ONE, NATIONAL ASSOCIATION,
as Trustee
By: _________________________________
Name: ________________________
Title: ________________________
cc: Village of Xxxxxx
J - 2
EXHIBIT K
OPTION RIGHTS REQUEST FORM
State of Illinois )
) ss.
County of Xxxx )
The affiant, __________, __________ of CenterPoint Intermodal LLC,
an Illinois limited liability company (the "Developer"), being duly sworn on
oath deposes and says pursuant to that certain Redevelopment Agreement dated
as of August 1, 2000 (the "Redevelopment Agreement") between the Developer
and the Village of Xxxxxx, Will County, Illinois (the "Village") and that
certain Escrow Agreement dated as of ____________, 2000 (the "Escrow
Agreement") among the Village, BANK ONE, NATIONAL ASSOCIATION, as escrow
agent (the "Escrow Agent"), the Developer and CenterPoint Realty Services, a
___________________ ("Realty"), as follows:
A. This Paragraph A sets forth and is a true and complete statement of
all expenditures for the TIF Project (as defined in the Indenture) to date:
Description Amount
----------- ------
Total $______________
B. The work paid for by the expenditures described in Paragraph A has
been completed.
C. This Paragraph C sets forth and is a true and complete statement of
the aggregate amount paid by the Village to the Developer to date as
reimbursement for TIF Funded Improvements paid by the Developer for the TIF
Project:
Original Principal Amount of Series 2000A Notes $______________
Project Reimbursement Requests ______________
Option Rights Requests ______________
Total $______________
D. The Developer requests reimbursement for the following TIF Funded
Improvements:
$______________
E. None of the TIF Funded Improvements referenced in Paragraph D above
have been previously reimbursed by the Village.
K - 1
F. The total amount referenced in Paragraph D above represents the
actual amount payable to (or paid to) the general contractor and/or
subcontractors who have performed work on the TIF Project, and/or their payees.
G. As provided in the Redevelopment Agreement, by virtue of the payment
or incurrence of the reimbursable costs described in Paragraph D, the Developer
shall be deemed to have purchased the Option Rights Certificates in an amount to
be determined consistent with Section 4.02(d) of the Redevelopment Agreement and
the Trustee is therefore hereby requested to authenticate and deliver Option
Rights Certificates which correspond to $____________ principal amount of TIF
Notes, such certification to be in the form of an Option Rights Certificate as
otherwise provided in the Indenture.
H. The Developer has approved all work and materials for the amount
referenced in Paragraph D above, and such work and materials conform to the
Plans and Specifications (as defined in the Redevelopment Agreement) as such may
be amended if request is in connection with the TIF Project.
I. The representations and warranties contained in the Redevelopment
Agreement are true and correct in each material respect and the Developer is in
compliance with all material covenants and contained therein.
J. No Event of Default under the Redevelopment Agreement exists.
K. The undersigned is an Authorized Developer Representative (as
defined in the Indenture).
All capitalized terms which are not defined herein have the meanings
given such terms in the Escrow Agreement.
Dated: _________, 200_.
CENTERPOINT INTERMODAL LLC,
an Illinois limited liability company
By: _________________________________
Name: ______________________________
Title: ______________________________
Subscribed and sworn before me this
_________ day of _________ , 2000.
_____________________________________
Notary Public
My commission expires: ________________
ACCEPTED:
BANK ONE, NATIONAL ASSOCIATION,
as Trustee
K - 2
By: _________________________________
Name: _______________________________
Title: ________________________
cc: Village of Xxxxxx
K - 3
