Design-Build Amendment #1
AIA® Document A141TM - 2014 Exhibit A
This Amendment #1 is dated as of December 23, 2019 and is incorporated into the accompanying AIA Document A141™-2014, Standard Form of Agreement Between Owner and Design-Builder dated the « 24 » day of « July » in the year « 2019 » (the “Agreement”)
(In words, indicate day, month and year.)
for the following PROJECT:
(Name and location or address)
« Fox GA Factory »
« 0000 Xxxx Xxxx Xx SW »
« Gainesville GA 30504 »
« The Agreement referred to the Project as “An ~ 309k SF factory located in Gainesville Industrial Park West”. That is now amended to read as follows: “An ~ 336k SF factory located in Gainesville Industrial Park West”. »
THE OWNER:
(Name, legal status and address)
« Fox Factory Inc »
« a CA corporation »
« 0000 Xxx 00 »
« Braselton GA 30517 »
THE DESIGN-BUILDER:
(Name, legal status and address)
« Xxxxxxx Xxxxxx Construction Co »
« a GA corporation »
« PO Box 1438
« Gainesville, GA 30503 »
The Owner and Design-Builder hereby amend the Agreement as follows.
TABLE OF ARTICLES
A.1 | CONTRACT SUM |
A.2 | CONTRACT TIME |
A.3 | INFORMATION UPON WHICH AMENDMENT IS BASED |
A.4 | DESIGN-BUILDER’S PERSONNEL, CONTRACTORS AND SUPPLIERS |
A.5 | COST OF THE WORK |
ARTICLE A.1 CONTRACT SUM
§ A.1.0 This Amendment #1 is for the portions of / Work for the Project as reflected in the Package proposals listed in §A.1.2.1. It is acknowledged that future amendments to the Agreement will be required and forthcoming to cover additional Work required to complete the Project.
§ A.1.1 The Owner shall pay the Design-Builder the Contract Sum in current funds for the Design-Builder’s performance of the Contract after the execution of this Amendment. The Contract Sum shall be one of the following and shall include compensation the Owner paid the Design-Builder for Work performed prior to execution of this Amendment and pursuant to the Letter of Intent between the parties dated May 29, 2019. This Amendment supersedes the Letter of Intent.
(Check the appropriate box.)
[ « X » ] | Stipulated Sum, in accordance with Section A.1.2 below |
[ « » ] | Cost of the Work plus the Design-Builder’s Fee, in accordance with Section A.1.3 below |
[ « » ] | Cost of the Work plus the Design-Builder’s Fee with a Guaranteed Maximum Price, in accordance with Section A.1.4 below |
(Based on the selection above, complete Section A.1.2, A.1.3 or A.1.4 below.)
§ A.1.2 Stipulated Sum
§ A.1.2.1 The Stipulated Sum shall be « Thirty-Six Million Five Hundred Five Thousand Eight Hundred Sixty-Three & 00/100 Dollars » ($ « 36,505,863.00»), subject to authorized adjustments as provided in the Design-Build Documents.
The Stipulated Sum is broken down as set forth in the following Exhibits:
Site Package Proposal Dated May 23,2019 attached as Exhibit No. 1.A.01
Shell/Structure Proposal Dated July 23,2019 attached as Exhibit No. 1.A.02
Design Services Fee Proposal Dated August 14, 2019 attached as Exhibit No. 1.A.03
100% CD’s Package I Proposal Dated October 22,2019 attached as Exhibit No. 1.A.04
§ A.1.2.2 The Stipulated Sum is based upon the following alternates, if any, which are described in the Design-Build Documents and are hereby accepted by the Owner:
(State the numbers or other identification of accepted alternates. If the Owner is permitted to accept other alternates subsequent to the execution of this Amendment, attach a schedule of such other alternates showing the change in Stipulated Sum for each and the deadline by which the alternate must be accepted.)
§ A.1.2.3 Unit prices, if any: If used, shall be included and defined within the component packages.
(Identify item, state the unit price, and state any applicable quantity limitations.)
Item | Units and Limitations | Price per Unit ($0.00) |
N/A | ||
§ A.1.3 Cost of the Work Plus Design-Builder’s Fee [Intentionally Deleted]
§ A.1.4 Cost of the Work Plus Design-Builder’s Fee with a Guaranteed Maximum Price [Intentionally Deleted]
§ A.1.5 Payments
§ A.1.5.1 Progress Payments
§ A.1.5.1.1 Based upon Applications for Payment submitted to the Owner by the Design-Builder, the Owner shall make progress payments on account of the Contract Sum to the Design-Builder as provided below and elsewhere in the Design-Build Documents.
§ A.1.5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows:
« »
§ A.1.5.1.3 Provided that an Application for Payment is received not later than the « 25th » day of the month, the Owner shall make payment of the certified amount to the Design-Builder not later than the « 25th » day of the « following » month. If an Application for Payment is received by the Owner after the application date fixed above, payment shall be made by the Owner not later than « Thirty » (« 30 ») days after the Owner receives the Application for Payment.
(Federal, state or local laws may require payment within a certain period of time.)
§ A.1.5.1.4 [Intentionally Deleted].
§ A.1.5.1.5 With each Application for Payment where the Contract Sum is based upon a Stipulated Sum, the Design-Builder shall submit the most recent schedule of values in accordance with the Design-Build Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. Compensation for design services, if any, shall be shown separately. The schedule of values shall be prepared in such form and supported by such data to substantiate its accuracy as the Owner may require. This schedule of values, unless objected to by the Owner, shall be used as a basis for reviewing the Design-Builder’s Applications for Payment.
§ A.1.5.1.6 In taking action on the Design-Builder’s Applications for Payment, the Owner shall be entitled to rely on the accuracy and completeness of the information furnished by the Design-Builder and shall not be deemed to have made a detailed examination, audit or arithmetic verification of the documentation submitted in accordance with Sections A.1.5.1.4 or A.1.5.1.5, or other supporting data; to have made exhaustive or continuous on-site inspections; or to have made examinations to ascertain how or for what purposes the Design-Builder has used amounts previously paid. Such examinations, audits and verifications, if required by the Owner, will be performed by the Owner’s auditors acting in the sole interest of the Owner.
§ A.1.5.1.7 Except with the Owner’s prior approval, the Design-Builder shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site.
§ A.1.5.1.8 If all or part of any funds of the Design-Builder that are held by the Owner, whether it be retainage, escrowed funds or otherwise, should be attached, garnished or levied upon under any order of court, or if the delivery thereof shall be stayed or enjoined by any order of court, or if any other writ, order, judgment, or decree shall be made or entered by any court affecting the held funds, or any part thereof whether with or without jurisdiction, and in case Owner obeys and complies with any such writ, order judgment, or decree, Owner shall not be liable to the Design-Builder, its successors, or assigns, and Design-Builder shall indemnify and hold Owner harmless for its compliance with such writ, order, judgment or decree, notwithstanding that such writ, order, judgment or decree be subsequently reversed, modified, annulled, set aside, or vacated.
§ A.1.5.2 Progress Payments-Stipulated Sum
§ A.1.5.2.1 Applications for Payment where the Contract Sum is based upon a Stipulated Sum shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment.
§ A.1.5.2.2 Subject to other provisions of the Design-Build Documents, the amount of each progress payment shall be computed as follows:
.1 | Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of « Ten » percent ( « 10 » %) on the Work. Pending final determination of cost to the Owner of Changes in the Work, amounts not in dispute shall be included as provided in Section 6.3.9 of the Agreement; |
.2 | Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage of « Ten » percent ( « 10 » %); |
.3 | Subtract the aggregate of previous payments made by the Owner; and |
.4 | Subtract amounts, if any, the Owner has withheld or nullified, as provided in Section 9.5 of the Agreement. |
§ A.1.5.2.3 The progress payment amount determined in accordance with Section A.1.5.2.2 shall be further modified under the following circumstances:
.1 | Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to the full amount of the Contract Sum, less such amounts as the Owner shall determine for incomplete Work, retainage applicable to such work and unsettled claims; and |
(Section 9.8.6 of the Agreement discusses release of applicable retainage upon Substantial Completion of Work.)
.2 | Add, if final completion of the Work is thereafter materially delayed through no fault of the Design-Builder, any additional amounts payable in accordance with Section 9.10.3 of the Agreement. |
§ A.1.5.2.4 Reduction or limitation of retainage, if any, shall be as follows:
(If it is intended, prior to Substantial Completion of the entire Work, to reduce or limit the retainage resulting from the percentages inserted in Sections A.1.5.2.2.1 and A.1.5.2.2.2 above, and this is not explained elsewhere in the Design-Build Documents, insert provisions here for such reduction or limitation.)
« Retainage withholding may be reduced to 5% upon reaching 75% completion of the Work. »
§ A.1.5.3 Progress Payments-Cost of the Work Plus a Fee [Intentionally Deleted]
§ A.1.5.4 Progress Payments-Cost of the Work Plus a Fee with a Guaranteed Maximum Price [Intentionally Deleted.
§ A.1.5.5 Final Payment
§ A.1.5.5.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Design-Builder not later than 30 days after the Design-Builder has fully performed the Contract and the requirements of Section 9.10 of the Agreement have been satisfied, except for the Design-Builder’s responsibility to correct non-conforming Work discovered after final payment or to satisfy other requirements, if any, which extend beyond final payment.
§ A.1.5.5.2 [Intentionally Deleted].
ARTICLE A.2 CONTRACT TIME
§ A.2.1 Contract Time, as defined in the Agreement at Section 1.4.13, is the period of time, including authorized adjustments, for Substantial Completion of the Work.
§ A.2.2 The Design-Builder shall achieve Substantial Completion of the Work not later than August 5, 2020. Additionally, Design-Builder shall achieve the following milestone completion dates:
« »
Portion of Work | Milestone Substantial Completion Date | |
Assembly Area | 03/31/2020 | |
First Floor Mezzanine Area | 06/29/2020 | |
Fabrication Area | 04/28/2020 | |
Second Floor Mezzanine Area & Site | 08/05/2020 | |
, subject to adjustments of the Contract Time as provided in the Design-Build Documents.
It is anticipated that the above milestone completion dates will be addressed in the next amendment as the Design-Build Documents are nearing completion.
Design-Builder hereby discloses to Owner that seventeen (17) rain delay days have been incurred since mobilization on June 10, 2019. The above Milestone Substantial Completion Dates shall be extended to account for rain delay days prior to the imposition of any liquidated damages. Design-Builder shall not be assessed liquidated damages for delay days caused by the failure of Owner supplied trades and/or infrastructure installations that do not meet collective critical path scheduling that are beyond the control of Design-Builder. Design-Builder to give advance notice to Owner of any concerns as soon as they arise.
(Insert provisions, if any, for liquidated damages relating to failure to achieve Substantial Completion on time or for bonus payments for early completion of the Work.)
« If the Design-Builder fails to achieve Substantial Completion of the Work within the Contract Time or by a milestone substantial completion date, Design-Builder shall be subject to liquidated damages (not a penalty) as follows: a) for a milestone substantial completion date missed by five (5) calendar days or more - $1,500 per calendar day for the total number of days the Work is delayed beyond the milestone substantial completion date, and/or
b) $2,500.00 per calendar day for the total number of days the Work is delayed beyond the Substantial Completion date.
Such liquidated damages are hereby agreed to be a reasonable pre-estimate of damages the Owner will incur as a result of delayed completion of the Work and shall be Owner's sole and exclusive remedy for delayed completion of the Work but shall not be construed as a limitation of the Owner's other rights and remedies under this Agreement. The Owner may deduct liquidated damages from any unpaid amounts then or thereafter due Design-Builder. Any liquidated damages not so deducted shall be payable by the Design-Builder to the Owner upon demand. »
ARTICLE A.3 INFORMATION UPON WHICH AMENDMENT IS BASED
§ A.3.1 The Contract Sum and Contract Time set forth in this Amendment are based on the following:
General note for all items within Article A.3:
Each component pricing package will include a current document log, specification log, list of assumptions
and clarifications, and a breakdown of any allowances and contingencies included.
§ A.3.1.1 The Supplementary and other Conditions of the Contract:
Document | Title | Date | Pages |
N/A | |||
§ A.3.1.2 The Specifications:
(Either list the specifications here or refer to an exhibit attached to this Amendment.)
« See Exhibit 1.B »
Section | Title | Date | Pages |
§ A.3.1.3 The Drawings:
(Either list the drawings here or refer to an exhibit attached to this Amendment.)
« See Exhibit 1.C »
Number | Title | Date |
§ A.3.1.4 The Sustainability Plan, if any:
(If the Owner identified a Sustainable Objective in the Owner’s Criteria, identify the document or documents that comprise the Sustainability Plan by title, date and number of pages, and include other identifying information. The Sustainability Plan identifies and describes the Sustainable Objective; the targeted Sustainable Measures; implementation strategies selected to achieve the Sustainable Measures; the Owner’s and Design-Builder’s roles and responsibilities associated with achieving the Sustainable Measures; the specific details about design reviews, testing or metrics to verify achievement of each Sustainable Measure; and the Sustainability Documentation required for the Project, as those terms are defined in Exhibit C to the Agreement.)
Title | Date | Pages |
N/A | ||
Other identifying information:
« N/A »
§ A.3.1.5 Allowances and Contingencies:
(Identify any agreed upon allowances and contingencies, including a statement of their basis.)
.1 | Allowances |
« N/A »
.2 | Contingencies |
« Stipulated Sum includes a Contractor Contingency in amount of One Million Four Hundred Ninety Thousand Three Hundred Fifty-Eight & 62/100 Dollars ($1,490,358.62) for the purpose of covering unexpected costs not included in a Changer Order. If said Contingency is not utilized by Contractor, the Stipulated Sum shall be reduced by Change Order by any such amount not utilized. »
§ A.3.1.6 Design-Builder’s assumptions and clarifications:
« None »
§ A.3.1.7 Deviations from the Owner’s Criteria as adjusted by a Modification:
« None »
§ A.3.1.8 To the extent the Design-Builder shall be required to submit any additional Submittals to the Owner for review, indicate any such submissions below:
« None »
ARTICLE A.4 DESIGN-BUILDER’S PERSONNEL, CONTRACTORS AND SUPPLIERS
§ A.4.1 The Design-Builder’s key personnel are identified below:
(Identify name, title and contact information.)
.1 | Superintendent |
« Xxxxx Xxxx »
.2 | Project Manager |
« Xxxxx Xxxxxxxx (Sr. PM)
Xxxxxx Xxxxxxxx (PM) »
.3 | Others |
« Xxxx Xxxxxx (Project Executive) »
§ A.4.2 The Design-Builder shall retain the following Consultants, Contractors and suppliers, identified below, if any:
(List name, discipline, address and other information.)
« »
ARTICLE A.5 COST OF THE WORK
§ A.5.1 Cost to Be Reimbursed as Part of the Contract [Intentionally Deleted]
§ A.5.2 Costs Not to Be Reimbursed as Part of this Contract [Intentionally Deleted].
§ A.5.3 Discounts, Rebates, and Refunds [Intentionally Deleted].
§ A.5.4 Other Agreements
§ A.5.4.1[Intentionally Deleted].
§ A.5.4.2 Agreements between the Design-Builder and Contractors shall conform to the applicable payment provisions of the Design-Build Documents, and shall not be awarded on the basis of cost plus a fee without the prior consent of the Owner. If an agreement between the Design Builder and a Contractor is awarded on a cost plus a fee basis, the Design-Builder shall provide in the agreement for the Owner to receive the same audit rights with regard to the Cost of the Work performed by the Contractor as the Owner receives with regard to the Design-Builder in Section A.5.5, below.
§ A.5.4.3 The agreements between the Design-Builder and Architect and other Consultants identified in the Agreement shall be in writing. These agreements shall be promptly provided to the Owner upon the Owner’s written request.
§ A.5.5 Accounting Records
The Design-Builder shall keep full and detailed records and accounts related to the cost of the Work and exercise such controls as may be necessary for proper financial management under the Contract and to substantiate all costs incurred. The accounting and control systems shall be satisfactory to the Owner. The Owner and the Owner’s auditors shall, during regular business hours and upon reasonable notice, be afforded access to, and shall be permitted to audit and copy, the Design-Builder’s records and accounts, including complete documentation supporting accounting entries, books, correspondence, instructions, drawings, receipts, subcontracts, Contractor’s proposals, purchase orders, vouchers, memoranda and other data relating to the Contract. The Design-Builder shall preserve these records for a period of three years after final payment, or for such longer period as may be required by law.
§ A.5.6 Relationship of the Parties
The Design-Builder accepts the relationship of trust and confidence established by this Agreement and covenants with the Owner to exercise the Design-Builder’s skill and judgment; to furnish efficient construction administration, management services and supervision; to furnish at all times an adequate supply of workers and materials; and to perform the Work in an expeditious and economical manner consistent with the Owner’s interests and the Contract.
This Amendment to the Agreement entered into as of the day and year first written above.
/s/ Xxxxxxx X. Xxxxxxxx | /s/ Xxxxxx Xxxxxxxxxx | |
OWNER (Signature) | DESIGN-BUILDER (Signature) | |
« Fox Factory Inc » « Xxxxxxx X Xxxxxxxx » « Chief Executive Officer » | « Xxxxxxx Xxxxxx Construction Co » « Xxxxxx Xxxxxxxxxx » « Chief Operating Officer » | |
(Printed name and title) | (Printed name and title) | |
EXHIBIT 1.A.1
Project: Fox Factory - 41 Acre
Date: 05.23.19
Owner: Fox Factory
SITE PACKAGE
Bid Package | Item Description | Sub 1 | Sub 2 | Sub 3 | Sub 4 | Sub 5 | Sub 6 | Delta (Low Vs. High) |
02 | Sitework & Utilities | Xxxxxxx | XX Xxxxxxx | CA Xxxxxx | Xxxx | $1,620,271 | ||
$3,319,111 | $3,345,411 | $4,822,459 | $4,939,382 | |||||
02A | Fencing | Gateway | Xxxxx-Xxxxxxx | Natural Enclosures | C&C Fence | $100,743 | ||
$150,735 | $205,522 | $233,410 | $251,478 | |||||
02B | Striping | Park-Rite | Brown's Asphalt | Xxxxx Xxxx | $2,002 | |||
$33,306 | $33,404 | $35,308 | ||||||
02C | Paving | Sunbelt | Allied Paving | Xxxxxxx | Xxxxxxx Brothers | MHB Paving | Atlanta Paving | $455,022 |
$1,769,080 | $1,882,160 | $1,971,587 | $2,025,442 | $2,179,667 | $2,224,102 | |||
02D | Xxxx & Gutter | JD Concrete | Curb Co. | Upstate Curb | MHB Paving | $191,329 | ||
$335,163 | $337,402 | $355,492 | $526,492 | |||||
02E | Landscaping | ACS Landscape | Xxxxx Landscape | Ashford Gardeners | CMC Landscaping | Tri Scapes | $469,980 | |
$802,957 | $808,355 | $928,192 | $1,112,554 | $1,272,937 | ||||
SUBTOTAL | $6,410,352 | |||||||
General Conditions & General Requirements | $497,000 | |||||||
Meter & Tap Fees | $119,648 | |||||||
Permit Fees (LDP Only) | $6,713 | |||||||
NPDES Monitoring | $15,000 | |||||||
SUBTOTAL | $7,048,713 | |||||||
CM Fee (5%) | $352,435.66 | |||||||
Contingency | $370,057.45 | |||||||
P&P Bond | $71,495.10 | |||||||
TOTAL | $7,842,701 | |||||||
The contents of this report are strictly confidential and are provided solely for the intended recipient on the understanding that it will be held confidentially and not disclosed to any other party without the prior written consent of Xxxxxxx Xxxxxx Construction Company.
Xxxxxxx Xxxxxx Construction Company Page 1 Printed 11/20/2019
EXHIBIT 1.A.2
Project: Fox Factory - 41 Acre
Date: 07.23.19
Owner: Fox Factory
SHELL/STRUCTURE PACKAGE
Bid Package | Item Description | Sub 1 | Sub 2 | Sub 3 | Sub 4 | Delta (Low Vs. High) |
02 | Termite Treatment | Prime Pest | All Pro | Bug Busters | $5,284 | |
$6,466 | $8,083 | $11,750 | ||||
02 | Grading (rain leader tie in, footing spoils, loading dock backfill) | Xxxxxxx'x | N/A | |||
$128,000 | ||||||
03 | Concrete | T&M Tilt | Xxxxxx Concrete | Southeast Concrete | $127,680 | |
$4,255,987 | $4,347,657 | $4,383,667 | ||||
05 | Structural Steel | Piedmont Steel | King Steel | Xxxxx Ironworks | $197,924 | |
$2,147,563 | $2,331,885 | $2,345,487 | ||||
07 | TPO Roofing | Xxxxxxx Roofing | Roof Management | Tip Top | SHC Roofing | $571,605 |
$1,889,793 | $1,975,580 | $2,110,887 | $2,461,398 | |||
14 | Elevators | Thyssen Xxxxx | Xxxx | $12,358 | ||
$90,944 | $103,302 | |||||
15 | Plumbing | Xxxxxx Xxxx | Xxxx County | Xxxxxx | $86,075 | |
$440,451 | $509,091 | $526,526 | ||||
16 | Electrical | Xxxxxxxx Electric | CCE | Titan Electric | $177,208 | |
$371,488 | $376,470 | $548,696 | ||||
SUBTOTAL | $9,330,692 | $1,178,134 | ||||
General Conditions & General Requirements | $893,621 | |||||
Permit Fees (Shell & GDOT Bond) | $87,073 | |||||
3rd Party Testing | $150,000 | |||||
Surveying & Site As-Built | $85,000 | |||||
SUBTOTAL | $10,546,386 | |||||
CM Fee (5%) | $527,319.28 | |||||
Contingency (4.5%) | $474,587.35 | |||||
TOTAL | $11,548,292 | |||||
The contents of this report are strictly confidential and are provided solely for the intended recipient on the understanding that it will be held confidentially and not disclosed to any other party without the prior written consent of Xxxxxxx Xxxxxx Construction Company.
Xxxxxxx Xxxxxx Construction Company Page 1
Exhibit 1.A.03
BRPH
FEE PROPOSAL SUMMARY
We propose to perform the Architectural & Engineering Design and Construction Contract Administration Services for the following LUMP SUM:
BRPH Design and Construction Basic Services:
• | Task 1 - Programming $ 30,300.00 |
• | Task 2 - Conceptual Design $37,900.00 |
• | Task 3 - Design Development & Building Shell $378,000.00 |
• | Task 4 - Final Contract Documents $141,000.00 |
Task 5 - Construction Contract Administration $168,300.00
• | Task 6 - Fabrication Area Engineering $ 100,000.00 |
• | Task 7 - Anodizing Area Engineering $ 125,000.00 |
Subtotal $ 980,500.00
BRPH Reimbursable Expenses $ 10,000.00
TOTAL FEE (LUMP SUM) $ 990,500.00
The basic services do not include equipment utility layout or design & engineering of N+He piping, oil piping, anodizing line, fabrication machining, etc., structural engineering for cranes, civil site design or any scope that has not been defined as of June 04, 2019.
Additional Design to 08.14.19: $284,500.00 CM GC's & GR's: $127,500.00
To Total: $1,402,500.00
Exhibit 1.A.04
Project: Fox Factory - 41 Acre
Date: 10.22.2019
Owner: Fox Factory
100% CDs Package 1
Bid Package | Item Description | Sub 1 | Sub 2 | Sub 3 | Delta (Low Vs. High) |
08 | Glass & Glazing | Pro Service | Xxxxx Glass | Eastern | $288,040 |
$981,800 | $1,002,600 | $1,269,840 | |||
21 | Fire Suppression Systems | VSC | Gainesville Fire | Amber | $595,566 |
$454,434 | $543,000 | $1,050,000 | |||
22 | Plumbing | Xxxxxx | Xxxxxx Xxxx | Liquid Services | $134,942 |
$1,165,000 | $1,211,000 | $1,299,942 | |||
23 | HVAC | Xxxxxx | Georgia Mechanical | Conditioned Air | $165,000 |
$3,600,000 | $3,650,000 | $3,765,000 | |||
26 | Electrical | Titan | Xxxxxxxx | XX West | $1,029,671 |
$6,958,329 | $7,776,236 | $7,988,000 | |||
SUBTOTAL | $13,159,563 | $2,213,219 | |||
General Conditions & General Requirements | $1,182,920 | ||||
Permit Fees (100% CD Review) | $6,713 | ||||
SUBTOTAL | $14,349,196 | ||||
CM Fee (5%) | $717,459.80 | ||||
Contingency (4.5%) | $645,713.82 | ||||
TOTAL | $15,712,370 | ||||
The contents of this report are strictly confidential and are provided solely for the intended recipient on the understanding that it will be held confidentially and not disclosed to any other party without the prior written consent of Xxxxxxx Xxxxxx Construction Company.
Xxxxxxx Xxxxxx Construction Company Page 1
Exhibit 1.B
FOX FACTORY TABLE OF CONTENTS
BRPH ARCHITECTS-ENGINEERS, INC.
DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS
00 01 07 Seals Page 08-20-19
DIVISION 03 - CONCRETE
03 30 00 | Cast-in-Place Concrete | 08-20-19 |
03 36 19 | Penetrating Reactive Concrete Stain | 08-20-19 |
03 47 10 | Tilt-Up Concrete | 08-20-19 |
DIVISION 04 - MASONRY
04 22 00 Concrete Unit Masonry 08-20-19
DIVISION 05 - METALS
05 12 00 | Structural Steel | 08-20-19 |
05 21 00 | Steel Joists | 08-20-19 |
05 31 00 | Steel Deck | 08-20-19 |
05 40 00 | Cold-Formed Metal Framing | 08-20-19 |
05 50 00 | Metal Fabrications | 08-20-19 |
05 51 13 | Metal Pan Stairs | 08-20-19 |
05 52 13 | Pipe and Tube Railings | 08-20-19 |
DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES
06 10 53 Miscellaneous Rough Carpentry 08-20-19
DIVISION 07 - THERMAL AND MOISTURE PROTECTION
07 21 00 | Thermal Insulation | 08-20-19 |
07 26 00 | Vapor Retarders and Barriers | 08-20-19 |
07 42 13 | Metal Composite Material Wall Panels | 08-20-19 |
07 54 23 | Thermoplastic-Polyolefin (TPO) Roofing | 08-20-19 |
07 62 00 | Sheet Metal Flashing and Trim | 08-20-19 |
07 72 00 | Roof Accessories | 08-20-19 |
07 84 13 | Penetration Firestopping | 08-20-19 |
07 92 00 | Joint Sealants | 08-20-19 |
DIVISION 08 - OPENINGS
08 11 13 | Hollow Metal Doors and Frames | 08-20-19 |
08 14 16 | Flush Wood Doors | 08-20-19 |
08 33 23 | Overhead Coiling Doors | 08-20-19 |
08 33 29 | High-Performance Overhead Coiling Doors | 08-20-19 |
08 41 13 | Aluminum-Framed Entrances and Storefronts | 08-20-19 |
08 42 29 | Sliding Automatic Entrances | 08-20-19 |
C07609.002.00 TOC - i
08-20-19
BRPH ARCHITECTS-ENGINEERS, INC.
DIVISION 08 - OPENINGS (cont.)
08 44 13 | Glazed Aluminum Curtain Walls | 08-20-19 |
08 62 00 | Unit Skylights | 08-20-19 |
08 71 00 | Door Hardware | 08-20-19 |
08 80 00 | Glazing | 08-20-19 |
DIVISION 09 - FINISHES
09 29 00 | Gypsum Board | 08-20-19 |
09 91 23 | Interior Painting | 08-20-19 |
09 96 00 | High-Performance Coatings | 08-20-19 |
09 96 53 | Elastomeric Coatings | 08-20-19 |
DIVISION 10 - SPECIALTIES
10 14 00 | Signage | 08-20-19 |
10 21 13 | Stainless-Steel Toilet Compartments | 08-20-19 |
10 22 13 | Wire Mesh Partitions | 08-20-19 |
10 26 00 | Wall and Door Protection | 08-20-19 |
10 28 00 | Toilet, Bath, and Laundry Accessories | 08-20-19 |
10 44 00 | Fire Protection Specialties | 08-20-19 |
10 51 13 | Metal Lockers | 08-20-19 |
10 73 00 | Protective Covers | 08-20-19 |
DIVISION 11 - EQUIPMENT
11 13 19 Stationary Loading Dock Equipment 08-20-19
DIVISION 12 - FURNISHINGS
12 21 13 | Louver Blinds | 08-20-19 |
12 24 13 | Roller Window Shades | 08-20-19 |
12 32 16 | Manufactured Plastic-Laminate-Clad Casework | 08-20-19 |
12 35 53 | Plastic-Laminate-Clad Laboratory Casework | 08-20-19 |
DIVISION 14 - CONVEYING EQUIPMENT
14 24 00 Hydraulic Elevators 08-20-19
DIVISION 21 - FIRE SUPPRESION
21 05 00 | Common Work Results for Fire Suppression | 08-20-19 |
21 05 13 | Common Motor Requirements for Fire Suppression Equipment | 08-20-19 |
21 05 17 | Sleeves and Sleeve Seals for Fire-Suppression Piping | 08-20-19 |
21 05 18 | Escutcheons for Fire-Suppression Piping | 08-20-19 |
C07609.002.00 TOC - ii
08-20-19
BRPH ARCHITECTS-ENGINEERS, INC.
DIVISION 21 - FIRE SUPPRESSION (cont.)
21 05 23 | General-Duty Valves for Fire Protection Piping | 08-20-19 |
21 05 48 | Vibration and Seismic Controls for Fire- Suppression Piping and Equipment | 08-20-19 |
21 05 53 | Identification for Fire-Suppression Piping and Equipment | 08-20-19 |
21 08 00 | Commissioning of Fire Suppression | 08-20-19 |
21 11 00 | Facility Fire-Suppression Water-Service Piping | 08-20-19 |
21 11 19 | Fire Dpepartment Connections | 08-20-19 |
21 13 13 | Wet-Pipe Sprinkler Systems | 08-20-19 |
21 13 16 | Dry-Pipe Sprinkler Systems | 08-20-19 |
21 31 13 | Electric-Drive, Centrifugal Fire Pumps and Pressure-Maintenance Pumps | 08-20-19 |
DIVISION 22 - PLUMBING
22 05 17 | Sleeves and Sleeve Seals for Plumbing Piping | 08-20-19 |
22 05 29 | Hangers and Supports for Plumbing Piping and Equipment | 08-20-19 |
22 05 53 | Identification for Plumbing Piping and Equipment | 08-20-19 |
22 07 19 | Plumbing Piping Insulation | 08-20-19 |
22 13 16 | Sanitary Waste and Vent Piping | 08-20-19 |
22 13 19 | Sanitary Waste Piping Specialties | 08-20-19 |
22 13 23 | Sanitary Waste Interceptors | 08-20-19 |
22 14 23 | Storm Drainage Piping Specialties | 08-20-19 |
DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)
23 05 13 | Common Motor Requirements for HVAC Equipment | 08-20-19 |
23 05 29 | Hangers and Supports for HVAC Piping and Equipment | 08-20-19 |
23 05 48.13 | Vibration Controls for HVAC | 08-20-19 |
23 05 53 | Identification for HVAC Piping and Equipment | 08-20-19 |
23 05 93 | Testing, Adjusting, and Balancing for HVAC | 08-20-19 |
23 07 13 | Duct Insulation | 08-20-19 |
23 07 19 | HVAC Piping Insulation | 08-20-19 |
23 09 23 | Direct Digital Control (DDC) System for HVAC | 08-20-19 |
23 31 13 | Metal Ducts | 08-20-19 |
23 33 00 | Air Duct Accessories | 08-20-19 |
23 33 46 | Flexible Ducts | 08-20-19 |
23 34 16 | Centrifugal HVAC Fans | 08-20-19 |
23 34 23 | HVAC Power Ventilators | 08-20-19 |
23 36 00 | Air Terminal Units | 08-20-19 |
23 37 13.13 | Air Diffusers | 08-20-19 |
23 37 13.23 | Registers and Grilles | 08-20-19 |
C07609.002.00 TOC - iii
08-20-19
BRPH ARCHITECTS-ENGINEERS, INC.
DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC) (cont.)
23 37 16 | Fabric Air-Distribution Devices | 08-20-19 |
23 74 16.11 | Packaged, Small-Capacity, Rooftop Air-Conditioning Units (15-Tons and Under) | 08-20-19 |
23 81 26 | Split-System Air-Conditioners | 08-20-19 |
23 82 39.16 | Propeller Unit Heaters | 08-20-19 |
DIVISION 26 - ELECTRICAL
26 01 00 | Common Work Results for Electrical | 08-20-19 |
26 05 19 | Low-Voltage Electrical Power Conductors and Cables | 08-20-19 |
26 05 26 | Grounding and Bonding for Electrical Systems | 08-20-19 |
26 05 29 | Hangers and Supports for Electrical Systems | 08-20-19 |
26 05 33 | Raceways and Boxes for Electrical Systems | 08-20-19 |
26 05 36 | Cable Trays for Electrical Systems | 08-20-19 |
26 05 43 | Underground Ducts and Raceways for Electrical Systems | 08-20-19 |
26 05 44 | Sleeves and Sleeve Seals for Electrical Raceways and Cabling (Non-Fire Rated Application) | 08-20-19 |
26 05 53 | Identification for Electrical Systems | 08-20-19 |
26 05 73.13 | Short-Circuit Studies | 08-20-19 |
26 05 73.16 | Coordination Studies | 08-20-19 |
26 05 73.19 | Arc-Flash Hazard Analysis | 08-20-19 |
26 08 00 | Commissioning of Electrical Systems | 08-20-19 |
26 09 24 | Digital Network Lighting Controls | 08-20-19 |
26 09 43.23 | Relay-Based Ligghting Controls | 08-20-19 |
26 22 13 | Low-Voltage Distribution Transformers | 08-20-19 |
26 24 13 | Switchboards | 08-20-19 |
26 24 16 | Panelboards | 08-20-19 |
26 24 19 | Motor-Control Centers | 08-20-19 |
26 25 00 | Enclosed Bus Assemblies | 08-20-19 |
26 27 13 | Electricity Metering | 08-20-19 |
26 27 26 | Wiring Devices | 08-20-19 |
26 28 13 | Fuses | 08-20-19 |
26 28 16 | Enclosed Switches and Circuit Breakers | 08-20-19 |
26 29 13.06 | Soft-Start Motor Contorllers | 08-20-19 |
26 29 23 | Variable-Frequency Motor Controllers | 08-20-19 |
26 32 13.16 | Gaseous Emergency Engine Generators | 08-20-19 |
26 33 43 | Battery Chargers | 08-20-19 |
26 36 00 | Transfer Switches | 08-20-19 |
26 43 13 | Surge Protection Devices (SPDs) | 08-20-19 |
26 51 19 | LED Interior Lighting | 08-20-19 |
C07609.002.00 TOC - iv
08-20-19
BRPH ARCHITECTS-ENGINEERS, INC.
DIVISION 26 - ELECTRICAL (cont.)
26 52 13 | Emergency and Exit Lighting | 08-20-19 |
26 56 19 | LED Exterior Lighting | 08-20-19 |
26 56 00 | Exterior Lighting | 08-20-19 |
DIVISION 27 - COMMUNICATIONS
27 05 26 | Grounding and Bonding for Communicatoins Systems | 08-20-19 |
27 05 28 | Pathways for Communications Systems | 08-20-19 |
27 05 29 | Hangers and Supports for Communications Systems | 08-20-19 |
27 05 36 | Cable Trays for Communications Systems | 08-20-19 |
27 05 43 | Underground Pathways and Structures for Communication Systems | 08-20-19 |
27 05 44 | Sleeves and Sleeve Seals for Communications Pathways and Cabling | 08-20-19 |
27 05 53 | Identification for Communications Systems | 08-20-19 |
27 11 00 | Communications Equipment Room Fittings | 08-20-19 |
DIVISION 28 - ELECTRONIC SAFETY AND SECURITY
28 46 21.11 Addressable Fire-Alarm Systems 08-20-19
END OF TABLE OF CONTENTS
C07609.002.00 TOC - v
08-20-19
Exhibit 1.C Document Log 08.20.19 IFC Documents
