DEVELOPMENT FINANCING AGREEMENT
THIS AGREEMENT, made and entered into effective as of this 30 day
of June, 2000, by and between Razzoo's, Inc. (hereinafter
referred to as "Lessee"), whose address is 00000 Xxxxxx Xxxxxxx,
Xxxxx 000, Xxxxx Xxxxxx, XX 00000, and AEI Private Net Lease
Millennium Fund Limited Partnership ("Millennium Fund"), AEI Real
Estate Fund XVIII Limited Partnership ("Fund XVIII"), AEI Net
Lease Income & Growth Fund XIX Limited Partnership ("Fund XIX"),
and AEI Income & Growth Fund 23 LLC ("Fund 23") whose principal
business address is 1300 Minnesota World Trade Center, 00 Xxxx
Xxxxxxx Xxxxxx, Xx. Xxxx, Xxxxxxxxx 00000 (hereinafter referred
to as "Lessor") .
W I T N E S S E T H, that:
WHEREAS, Lessee is contemplating building the following
Improvements on the premises described in Exhibit "A" attached
hereto :
Construction of a building and improvements to be used as a
Razzoo's Cajun Caf
Restaurant.
WHEREAS, Lessee has made application to Lessor for
development financing to defray the costs of constructing such
Improvements;
WHEREAS, Lessor has issued to Lessee its Development
Financing and Leasing Commitment to advance funds in the amount
hereinafter specified, subject to compliance with the terms and
conditions of this Development Financing Agreement and the Net
Lease Agreement (the "Lease") of even date herewith;
NOW, THEREFORE, in consideration of entering into the Lease
and other good and valuable consideration, the receipt of which
is hereby acknowledged by the parties hereto, the parties hereto
agree as follows:
ARTICLE I
DEFINITIONS
For purposes of this Agreement, the following terms shall
have the following meanings:
1. "Application" shall mean Lessee's application to the
Lessor for the Development Financing the terms and conditions
of which are incorporated herein by reference.
2. "Architect's Contract" shall mean Lessee's contract with
the Project Architect.
3. "Commitment" shall mean Lessor's Commitment to Lessee
agreeing to provide the Development Financing. (The
"Development Financing and Leasing Commitment" dated of even
date herewith.)
4. "Completion Date" shall mean midnight, January 31, 2001,
subject to Force Majeure, as defined herein.
5. "Construction Costs" shall mean land costs, all costs
paid to construct and complete the Improvements, as specified
on Exhibit "B" attached hereto and made a part hereof.
6. "Construction Contracts" shall mean the contracts between
Lessee and Contractors for the furnishing of labor, services
or materials to the Leased Premises in connection with the
construction of the Improvements.
7. "Contractors" shall mean those firms directly engaged by
Lessee to construct the Improvements, whether one or more.
8. "Contract Documents" shall mean the Project Architect's
Contract, Plans and Specifications and the contract with the
Contractor.
9. "Development Financing" shall mean the funds to be made
available pursuant to the Commitment and not to exceed the
lesser of the Construction Costs or the maximum loan amount
of Three Million Eight Hundred Thirty Thousand Dollars
($3,830,000) as specified in the Commitment.
10. "Development Financing and Carrying Charges" shall mean
all fees, taxes and charges incurred under the Development
Financing and in the construction of the Improvements
including, but not limited to, interest charges, service and
inspection fees, attorney's fees, title insurance fees and
charges, recording fees and insurance premiums.
11. "Development Financing Documents" shall mean this
Agreement, the Lease, Assignment of Architects and
Construction Contracts, Guarantees, and such other documents
given to the Lessor as security for the Development
Financing.
12. "LTIC-CDD" shall mean Lawyers Title Insurance Corporation
- Construction Disbursement Department, the nationally
recognized title insurer, to be LTIC-CDD under the
Development Financing Disbursement Agreement executed by and
between the parties of even date herewith.
13. "Final Disbursement Date" shall mean the date of the
final disbursement of the Development Financing provided
hereunder.
14. "Improvements" shall mean the structures and other
improvements to be constructed on the Leased Premises in
accordance with the Plans and Specifications.
15. "Initial Disbursed Funds" shall mean those funds
disbursed on the Closing Date for land acquisition and
related soft costs upon Lessor's acquisition of the Leased
Premises.
16. "Inspecting Architect" shall mean the architect, if any,
hired by Lessor to perform inspections of the premises. An
Inspecting Architect may only be engaged by Lessor in the
event of a default relating to construction of the
Improvements under the Development Financing Documents.
17. "Leased Premises" shall mean the real property described
in the Exhibit "A" attached to this Agreement, together with
all Improvements, equipment and fixtures thereon.
18. "Lessee Equity" shall mean the final Construction Costs
less the amount of the Development Financing, and shall
include $142,000 of Lessee's funds that shall be dispersed to
fund the first $142,000 of construction costs incurred. Such
infusion of Lessee Equity shall be demonstrated by Draw
Requests and evidence of payment thereof by Lessee until such
$142,000 shall be infused by Lessee. To the extent that the
final Total Project Costs plus Lessee Equity shall be equal
to or less than Three Million Eight Hundred Thirty Thousand
Dollars, Lessee shall be reimbursed for Lessee Equity on the
Final Disbursement Date. Pursuant to the Lease, all
improvements constructed with Lessee Equity shall be the
property of the Lessor.
19. "Plans and Specifications" shall mean the plans and
specifications prepared by the Project Architect who shall be
licensed in the jurisdiction of the Leased Premises and
selected by Lessee.
20. "Project" shall mean the construction of the Improvements
on the Leased Premises.
21. "Project Architect" shall mean the architect retained by
Lessee to design and supervise construction of the
Improvements.
22. "Rental Modification Date" shall mean a date one hundred
and fifty days (150) from the date hereof.
23. "Sub-Contractors" shall mean those persons furnishing
labor or materials for the Project pursuant to the Sub-
Contracts.
24. "Sub-Contracts" shall mean the contracts between the
Contractor and its materialmen and mechanics in the
furnishing of labor or materials for the Project.
25. "Title" shall mean Lawyers Title Insurance Corporation
issuing the Lessor's fee owner's title insurance policy.
ARTICLE II
THE DEVELOPMENT FINANCING
Subject to compliance with the provisions of this Agreement,
Lessor agrees to advance to Lessee, and Lessee agrees to request
from Lessor, the Development Financing. The Development
Financing shall be advanced in stages by Lessor to LTIC-CDD and
disbursed by LTIC-CDD pursuant to the provisions of Article VIII
hereof. The Development Financing, or so much thereof as has
been advanced hereunder, shall bear interest at the rate and
shall be repaid in accordance with the terms hereof and the
Lease. The proceeds of the Development Financing shall be used
exclusively for the purposes of defraying Construction Costs.
ARTICLE III
N/A
ARTICLE IV
CONSTRUCTION OF IMPROVEMENTS
Lessee agrees to commence construction of the Improvements
within thirty (30) days from the date of this Agreement. After
commencement of construction of any Improvements, Lessee agrees
to diligently pursue said construction to completion, and to
supply such moneys and to perform such duties as may be necessary
to complete the construction of said Improvements pursuant to the
Plans and Specifications and in full compliance with all terms
and conditions of this Agreement and the Development Financing
Documents, all of which shall be accomplished on or before the
Completion Date, subject to Force Majeure and without liens,
claims or assessments (actual or contingent) asserted against the
Leased Premises for any material, labor or other items furnished
in connection therewith, subject to Lessee's right to contest
such liens, claims, or assessments provided the same are removed
as a lien upon the Leased Premises prior to foreclosure of such
lien, and all in full compliance with all construction, use,
building, zoning and other similar requirements of any pertinent
governmental jurisdiction. Lessee will provide to Lessor, upon
request, evidence of satisfactory compliance with all the above
requirements.
ARTICLE V
REPRESENTATIONS AND WARRANTIES OF THE LESSEE
Lessee hereby represents and warrants to the Lessor, which
representations and warranties shall be deemed to be restated by
Lessee each time Lessor makes an advance of the Development
Financing, that:
1. VALIDITY OF DEVELOPMENT FINANCING DOCUMENTS - The Development
Financing Documents are in all respects legal, valid and binding
according to their terms.
2. NO PRIOR LIEN ON FIXTURES - No mortgage, xxxx of sale,
security agreement, financing statement, or other title retention
agreement (except those executed in favor of Lessor) has been, or
will be, executed with respect to any fixture (except Lessee's
trade fixtures not financed with this Development Financing) used
in conjunction with the construction, operation or maintenance of
the improvements.
3. CONFLICTING TRANSACTION OF LESSEE - The consummation of the
transactions hereby contemplated and the performance of the
obligations of Lessee under and by virtue of the Development
Financing Documents will not result in any breach of, or
constitute a default under, any mortgage, lease, bank loan or
credit agreement, corporate charter, by-laws, partnership
agreement, or other instrument to which Lessee is a party or by
which it may be bound or affected, the breach of which would
materially affect Lessee's ability to perform its obligations
hereunder.
4. PENDING LITIGATION - There are no actions, suits or
proceedings pending, or to the knowledge of Lessee threatened,
against or affecting it or the Leased Premises, or involving the
validity or enforceability of any of the Development Financing
Documents, at law or in equity, or before or by any governmental
authority, except actions, suits and proceedings that are fully
covered by insurance or which, if adversely determined would not
substantially impair the ability of Lessee to perform each and
every one of its obligations under and by virtue of the
Development Financing Documents; and to the Lessee's knowledge it
is not in default with respect to any order, writ, injunction,
decree or demand of any court or any governmental authority.
5. VIOLATIONS OF GOVERNMENTAL LAW, ORDINANCES OR REGULATIONS -
To the best knowledge of Lessee, there are no violations or
notices of violations of any federal or state law or municipal
ordinance or order or requirement of the State in which the
Leased Premises are located or any municipal department or other
governmental authority having jurisdiction affecting the Leased
Premises, which violations in any way have a material adverse
affect on the Leased Premises and which remain uncured after
notice by such governmental authority or department (if notice is
required) and the expiration of the time within which Lessee may
cure such violation, or if no time limitation is specified,
within a reasonable time after notice to cure such violation .
6. COMPLIANCE WITH ZONING ORDINANCES AND SIMILAR LAWS - To the
best knowledge of Lessee, the Plans and Specifications and
construction pursuant thereto and the use of the Leased Premises
contemplated thereby comply and will comply with all present
governmental laws and regulations and requirements, zoning
ordinances, standards, and regulations of all governmental bodies
exercising jurisdiction over the Leased Premises. Lessee agrees
to provide the Project Architect's certification to such effect
prior to the funding of the first disbursement under the
Development Financing.
7. LESSEE'S STATUS AND AUTHORITY - If the Lessee be a
corporation, limited liability company, trust or a partnership,
Lessee warrants and represents that (i) it is duly organized,
existing and in good standing under the laws of the state in
which it is incorporated or created; (ii) it is duly qualified to
do business and is in good standing in the state in which the
Leased Premises are located; (iii) it has the corporate or other
power, authority and legal right to carry on the business now
being conducted by it and to engage in the transactions
contemplated by this Agreement and the Development Financing
Documents; and (iv) the execution and delivery of this Agreement
and the Development Financing Documents and the performance and
observance of the provisions hereof and thereof have been (or
future acts will be) duly authorized by all necessary trust,
partnership, or corporate actions of Lessee. Lessee will furnish
such resolutions, affidavits and opinions of counsel to such
effect as Lessor may reasonably require.
8. AVAILABILITY OF UTILITIES - All utility services necessary for
the construction of the Improvements will be available prior to
the commencement of construction, and all utility services
necessary for the proper operation of the Improvements for their
intended purposes are available at the Leased Premises or will be
available at the Leased Premises prior to the Final Disbursement
Date, at commercially comparable utility rates and hook-up
charges for the vicinity, including water supply, storm and
sanitary sewer facilities, gas, electricity and telephone
facilities. Lessee shall furnish evidence of such availability
of utilities from time to time at Lessor's request.
9. BUILDING PERMITS - All building permits required for the
construction of the Improvements have been obtained prior to the
commencement of the construction of the Improvements and copies
of same will be delivered to Lessor.
10. CONDITION OF LEASED PREMISES - The Leased Premises are
not now damaged or injured as a result of any fire, explosion,
accident, flood or other casualty, nor to the best of Lessee's
knowledge, subject to any action in eminent domain.
11. APPROVAL OF PLANS AND SPECIFICATIONS - To the best
knowledge of Lessee in reliance upon the Project Architect's
certification to such effect, the Plans and Specifications
conform to the requirements and conditions set out by applicable
law or any effective restrictive covenant, to all governmental
authorities which exercise jurisdiction over the Leased Premises
or the construction thereon, and no construction will be
commenced upon the Leased Premises until said Plans and
Specifications shall have been approved by Lessor, which consent
shall not be unreasonably withheld or delayed and shall be given
or withheld within ten business days after written request
therefor. Subject to Article VI, paragraph 14, no material
changes are to be made in the Plans and Specifications as
approved without Lessor's prior consent, which consent shall not
be unreasonably withheld or delayed and shall be given or
withheld within ten business days after written request therefor;
except, after prior written notice to Lessor, provided the
Development Financing shall remain in balance as set forth in
Article VII, paragraph 3 herein, Lessor shall consent to
reallocation among line items or use of the Construction
Contingency in the aggregate of not more than the amount budgeted
as set forth on Exhibit B for Construction Contingency, unless
Lessee shall deposit Owner Equity with LTIC-CDD in the amount of
such excess over the budgeted amount.
12. CONSTRUCTION CONTRACTS - Lessee has entered into
contracts with the Contractors or separate contracts with
materialmen and laborers providing for the construction of the
Improvements. Lessee will cause the Contractors to promptly
furnish Lessor with the complete list of all Sub-contractors or
entities as and when under contract, which Contractors propose to
engage to furnish labor and/or materials in constructing the
Improvements (such list containing the names, addresses, and
amounts of such sub-contracts as written in excess individually
of $5,000, and prior to disbursement of funds to or for the
benefit of such Subcontractors, affidavits of authorized
signatory and other documents commercially reasonably required by
Title to insure that the Leased Premises remain lien free) and
will from time to time furnish Lessor or Title with true copies
of all Contracts entered into by Lessee and with the terms of all
verbal agreements therefor, if any, and as to subcontractors,
letters signed by sub-contractors whose contracts are in excess
of $5,000 setting forth the present amount of their contract and
the amounts remaining to be paid under that contract, if the same
information is not stated on a lien waiver reflecting the most
currently requested payment to such subcontractor.
13. BROKERAGE COMMISSIONS - No brokerage commissions are due
in connection with the transaction contemplated hereby or if
there are commissions due or payable the same will be paid by
Lessee. Lessee agrees to and shall indemnify Lessor from any
liability, claims or losses arising by reason of any such
brokerage commissions. This provision shall survive the
repayment of the Development Financing and shall continue in full
force and effect so long as the possibility of such liability,
claims or losses exists.
14. NO PRIOR WORK - Except as may have been permitted by
Lessor, no work or construction has been commenced or will be
commenced by or on behalf of Lessee on the Leased Premises, nor
has Lessee entered into any contracts or agreements for such work
or construction which could result in the imposition of a
mechanic's or materialmen's lien on the Leased Premises or the
Improvements prior to or on parity with the interest of Lessor.
15. ENVIRONMENTAL IMPACT STATEMENT - All required
environmental impact statements as required by any governmental
authority having jurisdiction over the Leased Premises or the
construction of the Improvements have been duly filed and
approved.
16. ACCESS - The Leased Premises front on a publicly
maintained road or street or have access to such a road or street
under an easement or private way, which is not subject to a
reversion in favor of any party.
17. FINANCIAL INFORMATION - Any financial statements
heretofore delivered to Lessor are true and correct in all
respects, have been prepared in accordance with generally
accepted accounting practice, and fairly present the respective
financial conditions of the subject thereof as of the respective
dates thereof and no materially adverse change has occurred in
the financial conditions reflected therein since the respective
dates thereof.
ARTICLE VI
COVENANTS OF LESSEE
Lessee hereby covenants and agrees with Lessor as follows:
1. SURVEYS - Prior to execution of any Development Financing
Documents and prior to the initial request for a Disbursement (as
defined in Article VIII hereof), Lessee has furnished to Lessor
three copies of a current perimeter land survey, in form and
substance satisfactory to Lessor, certified to Lessor, giving a
description of the Leased Premises and showing all encroachments
onto or from the Leased Premises, currently certified by a
registered surveyor and bearing his registry number and showing
access rights, easements, or utilities, rights of way, all
setback requirements upon the Leased Premises, improvements,
matters affecting title and such other items as Lessor may
reasonably request.
2. TITLE INSURANCE - Prior to the initial request for
Disbursement the Lessee has furnished Lessor with an ALTA policy
of title insurance, and prior to any subsequent request for
Disbursement such ALTA policy of title insurance shall be brought
down to the date of Disbursement by endorsement, all in form and
substance satisfactory to Lessor issued at the Lessee's expense
and written by Title insuring the Leased Premises to be
marketable, free from exceptions for mechanic's and materialmen's
liens and free from other exceptions not previously approved by
the Lessor, naming Lessor as fee owner insured to the extent of
advances made hereunder subject only to such exceptions as may be
reasonably approved by Lessor.
3. RESTRICTIONS ON CONVEYANCE OR SECONDARY FINANCING - Lessee
will not transfer, sell, convey or encumber the Leased Premises
or subject the Leased Premises to any secondary financing in any
way without the written consent of the Lessor, except as
permitted in Article V, paragraph 2 relating to trade fixture
financing sources or suppliers.
4. INSURANCE - To obtain or cause Contractor to obtain and
maintain such insurance or evidence of insurance as Lessor may
reasonably require, including but not limited to the following:
(a) BUILDER'S RISK INSURANCE - Builder's Risk Insurance
written on the so-called "Builder's Risk-Completed Value
Basis" in an amount equal to the full replacement cost of the
Improvements at the date of completion with coverage
available on the so-called multiple peril form of policy,
including coverage against collapse and water damage, naming
Lessor as additional named insured, such insurance to be in
such amounts and form and written by such companies as shall
be reasonably approved by Lessor, and the originals of such
policies (together with appropriate endorsement thereto,
evidence of payment of premiums thereon and written
agreements by the insurer or insurers therein to give Lessor
ten (10) days' prior written notice of any intention to
cancel) shall be promptly delivered to Lessor, said insurance
coverage to be kept in full force and effect at all times
until the completion of construction of the Improvements.
(b) HAZARD INSURANCE - Fire and Extended Coverage Insurance,
and such other hazard insurance as Lessor may require and as
called for in the Lease in an amount equal to the full
replacement cost of the Improvements naming Lessor as an
additional named insured, such insurance to be in such
amounts and form and written by such companies as shall be
reasonably approved by Lessor, and the originals of such
policies (together with appropriate endorsements thereto,
evidence of payment of premiums thereon and written agreement
by the insurer or insurers therein to give Lessor ten (10)
days' prior written notice of any intention to cancel) shall
be promptly obtained and delivered to Lessor immediately upon
completion of the construction of the Improvements and before
any portion is occupied by Lessee or any tenant of Lessee
with such insurance to be kept in full force and effect at
all times thereafter.
(c) PUBLIC LIABILITY - Comprehensive public liability
insurance (including operations, contingent liability
operations, operations of sub- contractors, completed
operations and contractual liability insurance) in limits of
coverage as set forth in the Lease.
(d) WORKMEN'S COMPENSATION INSURANCE - Evidence of compliance
with the required coverage under statutory workmen's
compensation requirements.
5. COLLECTION OF INSURANCE PROCEEDS - To cooperate with Lessor in
obtaining for Lessor the benefits of any insurance or other
proceeds lawfully or equitably payable to it in connection with
the transaction contemplated hereby and the collection of any
indebtedness or obligation of the Lessee to Lessor incurred
hereunder (including the payment by Lessee of the expense of an
independent appraisal on behalf of Lessor in case of a fire or
other casualty affecting the Leased Premises).
6. APPLICATION OF DEVELOPMENT FINANCING PROCEEDS - To use the
proceeds of the Development Financing solely for the purpose of
paying for Construction Costs and such incidental costs relative
to the construction as may be reasonably approved from time to
time in writing by Lessor, and in no event to use any of the
Development Financing proceeds for personal, corporate or other
purposes.
7. EXPENSES - To pay all costs of closing the Development
Financing and all expenses of Lessor with respect thereto,
including, but not limited to, legal fees by Lessor's counsel and
all other reasonable attorney's fees (limited as set forth in the
Commitment), costs of title insurance, transfer taxes, license
and permit fees, recording expenses, surveys, intangible taxes,
appraisal fees, Inspecting Architect fees, expenses of retaking
possession upon default by Lessee hereunder or other costs of
enforcement (including reasonable attorney's fees) and similar
items.
8. LAWS, ORDINANCES AND ETC. - To comply promptly with any law,
ordinance, order, rule or regulation of all authorities
exercising jurisdiction over the Leased Premises or the
construction thereon, including appropriate supervising boards of
fire underwriters and similar agencies and the requirements of
any insurer issuing coverage on the Project.
9. RIGHT OF LESSOR TO INSPECT LEASED PREMISES - Upon 48 hours
notice, except in cases which Lessor reasonably deems to be an
emergency, in which event upon reasonable notice under the
circumstances, to permit Lessor and Title and their
representatives and agents to enter upon the Leased Premises and
to inspect the Improvements and all materials to be used in
construction thereof and to cooperate and cause Contractor to
cooperate with Lessor or Title and their representatives and
agents during such inspections, provided that such is
accomplished without interrupting the construction process.
Provided, further, however, that this provision shall not be
deemed to impose upon Lessor or Title any duty or obligation
whatsoever to undertake such inspections, to correct any defects
in the Improvements or to notify any person with respect thereto.
10. BOOKS AND RECORDS - To set up and maintain accurate and
complete books, accounts and records pertaining to the Project
including the working drawings in a manner reasonably acceptable
to Lessor. The Lessor, Title and Inspecting Architect shall have
the right at all reasonable times and upon reasonable prior
notice to inspect, examine and copy all books and records of
Lessee relating to the Project, and to enter and have free access
to the Leased Premises and Improvements and to inspect all work
done, labor performed and material furnished in or about the
Project, provided that such is accomplished without interrupting
the construction process. Notwithstanding the foregoing, Lessee
shall be responsible for making inspections as to the
Improvements during the course of construction and shall
determine to its own satisfaction that the work done or materials
supplied by the Contractors and all Subcontractors has been
properly supplied or done in accordance with the applicable
contracts. Lessee will hold Lessor and Title harmless from and
Lessor and Title shall have and have no liability or obligation
of any kind to Lessee or creditors of Lessee in connection with
any defective, improper or inadequate workmanship or materials
brought in or related to the Improvements or the Leased Premises,
or any mechanic's liens arising as a result of such workmanship
or materials. Upon Lessor's request, Lessee shall replace or
cause to be replaced any such work or material found to be
materially deficient by the Project Architect or Independent
Architect. Lessor shall cooperate with Lessee in obtaining any
rights under any applicable warranties to accomplish such work.
Any inspections made by Inspecting Architect, Title or Lessor are
for the sole benefit of Lessor and neither Lessee nor any
creditor, tenant or vendee of Lessee shall be entitled to rely on
such inspection. Lessee shall obtain for Lessor coincident
rights to rely upon any warranties obtain by Lessee from its
Contractors or subcontractors.
11. CORRECTION OF DEFECTS - To promptly correct any
structural defects in the Improvements or any material departure
from the Plans and Specifications not previously approved by
Lessor. The advance of any Development Financing proceeds shall
not constitute a waiver of Lessor's right to require compliance
with this covenant.
12. SIGN REGARDING DEVELOPMENT FINANCING - To allow Lessor to
erect and maintain at a suitable site on the Leased Premises, at
a location to be chosen by Lessee in its reasonable discretion, a
sign indicating that Development Financing is being provided by
Lessor, to the extent permitted by law or private covenant,
condition, or agreement affecting the Project.
13. ADDITIONAL DOCUMENTS - To furnish to Lessor all
instruments, documents, initial surveys, footing or foundation
surveys, if conducted, certificates, plans and specifications,
appraisals, financial statements, title and other insurance
reports and agreements and each and every other document and
instrument required to be furnished by the terms hereof, all at
Lessee's expense; to assign and deliver to Lessor such documents,
instruments, assignments and other writings, and to do such other
acts necessary or desirable to preserve and protect the Leased
Premises, as Lessor may require; and to do and execute all and
such further lawful and reasonable acts, conveyances and
assurances for the carrying out of the intents and purposes of
this Agreement, the Lease, or the Commitment, as Lessor shall
reasonably require from time to time.
14. ARCHITECTS AND CONSTRUCTION CONTRACTS - To commit no
default nor knowingly permit a default under the terms of the
Architects or Construction Contracts; To waive none nor knowingly
permit a waiver of the obligations of the parties thereunder; To
do no act which would relieve such parties from their obligations
thereunder; To make no amendments to such contracts, without the
prior written consent of Lessor; To enter into no change orders
or extras that cause a reallocation among budgeted line items, or
that in the aggregate or singularly result in a net increase in
excess of 10% of the original contract amount without Lessor's
prior written consent, which consent shall not be unreasonably
withheld or delayed; provided, however, Lessor shall be given
written notice and copies of all change orders; provided,
further, however, with written notice to Lessor prior to any
request for funds subsequent to any such change order or
reallocation, the Lessee shall be allowed to enter into any
change order or extra which is accounted for by use of any
reallocation among line items or any remaining budgeted
Contingency line item, or if the same has been exhausted, Lessee
shall be allowed increases in the original contract amount
without Lessor's consent if Lessee has, upon the execution of
said change order, deposited with Lessor the amount by which such
change order increases the total Construction Cost; To allow all
such contracts to be subject to the approval of Lessor for its
loan purposes; To allow Lessor to take advantage of all the
rights and benefits of the contracts upon any default by Lessee;
and to submit evidence to Lessor that both the Architect and the
Contractors will permit Lessor to acquire Lessee's interest under
their respective contracts and the Contract Documents without
additional charge or fee should an event of default occur
hereunder, which default is not cured within applicable notice
and cure periods.
15. ENFORCE PERFORMANCE OF SUB-CONTRACTS - To enforce, or
cause to be enforced, the prompt performance of the Sub-Contracts
in accordance with their terms and not to approve any changes in
the same that in the aggregate or singularly result in a net
increase in excess of 10% of the original General Contractor's
contract amount without Lessor's prior written consent, which
consent shall not be unreasonably withheld or delayed, provided
Lessee's right to enter into any such change order shall be on
the same terms set forth in Section 14 above.
16. COMPLIANCE WITH RULES - To comply with, and to require
the Contractors to comply with, all rules, regulations,
ordinances and laws bearing on the conduct of the work on the
Improvements, including the requirements of any insurer issuing
coverage on the Project and the requirements of any applicable
supervising boards of fire underwriters.
17. OPINIONS OF COUNSEL - To furnish such opinions of counsel
as may be reasonably requested of the Lessee in connection with
the matters contemplated by this Agreement.
18. SOIL TESTS - To provide the Lessor with a soil report
prepared by an acceptable engineer certifying as to the status of
the soil conditions on the Leased Premises, the need or lack of
need for special pilings and foundations and that either any
pilings and foundation necessary to support the Improvements have
been placed in a manner and quantity sufficient to provide the
required support or that no such pilings and foundations are
necessary for the support and construction of the Improvements.
19. MARKETABLE TITLE - To execute and deliver or cause to be
executed and delivered such instruments as may be required by the
Lessor and Title to provide Lessor with a marketable, valid title
to the Leased Premises subject only to such exceptions to title
as may be reasonably approved by Lessor.
20. VIOLATIONS OF GOVERNMENTAL LAW, ORDINANCES OR REGULATIONS
- Lessee will permit no violations nor commit the same, of any
federal or state law or municipal ordinance or order or
requirement of the State in which the Leased Premises are located
or any municipal department or other governmental authority
having jurisdiction affecting the Leased Premises, which
violations in any way have a material adverse affect on the
Leased Premises and which remain uncured after notice by such
governmental authority or department (if notice is required) and
the expiration of the time within which Lessee may cure such
violation, or if no time limitation is specified, within a
reasonable time after notice to cure such violation .
21. COMPLIANCE WITH ZONING ORDINANCES AND SIMILAR LAWS - The
Plans and Specifications and construction pursuant thereto and
the use of the Leased Premises contemplated thereby will comply
with all governmental laws and regulations and requirements,
zoning ordinances, standards, and regulations of all governmental
bodies exercising jurisdiction over the Leased Premises,
including environmental protection and equal employment
regulations, and appropriate supervising boards of fire
underwriters and similar agencies.
22. APPROVAL OF PLANS AND SPECIFICATIONS - The Plans and
Specifications will conform to the requirements and conditions
set out by applicable law or any effective restrictive covenant,
and to all governmental authorities which exercise jurisdiction
over the Leased Premises or the construction thereon.
ARTICLE VII
CONDITIONS PRECEDENT TO A DISBURSEMENT
It shall be a condition precedent to each Disbursement under this
Development Financing Agreement that:
1. DEVELOPMENT FINANCING DOCUMENTS - The Development Financing
Documents shall have been duly executed and delivered to Lessor
and shall be in full force and effect.
2. LESSEE EQUITY - Lessee shall have paid all of the Lessee
Equity funds into the Project before the first Disbursement (or
any subsequent Disbursement if additional Lessee Equity should be
required) and Lessee shall deliver evidence of such payment
reasonably satisfactory to Lessor.
3. DEVELOPMENT FINANCING BALANCE - As of the date immediately
prior to any Disbursement, the total amount of unadvanced
proceeds of the Development Financing shall be sufficient, in the
commercially reasonable opinion of Lessor (the opinion of Lessor
being based upon affidavit of the General Contractor, the Project
Architect, the Inspecting Architect, or other reliable licensed
third party contractor) to complete the Improvements free of
liens. To the extent the total of the unadvanced proceeds of the
Development Financing shall be insufficient, at any time, in
Lessor's reasonable opinion, (based upon the affidavit as set
forth above) to complete the Improvements, or be less than the
total Construction Costs not yet paid for or not yet incurred
(including interest accruing for the remainder of the term or
extensions thereof, if any), the Lessee shall immediately deposit
with the Lessor or with Title, as additional Lessee Equity funds,
an amount equal to such deficiency and such additional Lessee
Equity funds shall be disbursed by LTIC-CDD prior to the
Disbursement of any further advance or advances under this
Agreement.
4. NO DEFAULT - No event of default, which remains uncured after
the expiration of applicable cure periods, shall exist under this
Agreement or the Development Financing Documents.
5. REPRESENTATIONS AND WARRANTIES - The representations and
warranties in Article V hereof shall be true and correct on and
as of the date of each Disbursement.
6. COVENANTS - Lessee shall have complied with all of the
covenants made by it in Article VI hereof.
7. SWORN CONSTRUCTION STATEMENT - Prior to the initial
disbursement hereunder, the Lessee shall have submitted to Lessor
and Title a Construction Cost Statement or the Construction
Contract (if such information is contained therein) sworn to by
Lessee and Contractors reflecting all major Sub-Contractors or
materialmen who shall then be engaged in furnishing labor,
materials or supplies for the Improvements. The list should show
the name of each and every Contractor, Sub-Contractor and
materialman (or at least such entities or individuals whose
contract is in excess of $5,000), its address and an estimate of
the dollar value of the work, labor and materials to be done or
supplied and a general statement of the nature of the work to be
done or materials to be supplied by each Contractor. Thereafter,
if such list should change or new subcontractors shall execute
contracts not reflected on the above list, the Lessee shall
furnish to the Lessor any amendments or additions to the original
statement as so submitted.
8. APPLICATION FOR PAYMENT - Lessor shall have received an
Application for Payment pursuant to Article VIII hereof.
9. TITLE - Title shall issue its endorsement to the title policy
insuring the Lessor as fee owner under the policy in the
aggregate amounts of all prior Disbursements and the requested
Disbursement.
10. WORK IN PLACE - All work or materials for which a
Disbursement is requested shall be in place and incorporated into
the Improvements.
ARTICLE VIII
METHODS OF DISBURSEMENTS OF DEVELOPMENT FINANCING PROCEEDS
The Development Financing shall be disbursed (a "Disbursement")
as follows:
1. PROCEDURE - Not more often than monthly, Lessee may submit an
Application for Payment in the form attached hereto as Exhibit
"C" requesting the Disbursement of proceeds under the Development
Financing (a "Draw Request"), which request shall be submitted to
Lessor and to LTIC-CDD at least five (5) business days prior to
the date on which a Disbursement is requested. Provided the
conditions of this Development Financing Agreement are met on the
date requested for such advance, Lessor shall advance to LTIC-CDD
amounts certified to be currently payable by Lessee (excluding
the retainage hereinafter specified) for the then incurred
portion of Total Construction Costs pursuant to the Application
for Payment. All costs shall have been approved in writing by
the Project Architect, Lessee, Contractor, and if required by
Lessor, by the Inspecting Architect. All interest accruing need
not be disbursed to LTIC-CDD, but may be immediately and
automatically credited by Lessor to the Development Financing
account. LTIC-CDD shall disburse all funds advanced to it by
Lessor in accordance with the terms and provisions of this
Agreement and any special escrow requirements imposed by LTIC-CDD
as a condition to its acting as the disbursing agent hereunder.
The disbursed proceeds of the Development Financing shall bear
interest from and including the date of disbursement to LTIC-CDD
or the date of credit by Lessor provided that in the event LTIC-
CDD shall fail to disburse any advances within five (5) business
days after the date set for an advance, LTIC-CDD shall return
said advance to Lessor and interest on such advance shall xxxxx
from and after the date of such return. Any amounts disbursed to
LTIC-CDD and returned by LTIC-CDD to the Lessor shall not be
deemed to be advanced under the Development Financing Documents.
Each Application for Payment shall clearly set forth the amounts
due to Lessee and to each Contractor out of the requested
Development Financing and shall be accompanied by the following:
a. A Draw Request Certificate in the form attached hereto as
Exhibit "D" certifying that each contractor or materialman
for which payment is requested in the relevant Application
for Payment has satisfactorily completed the work or
furnished the materials for which payment is requested in
accordance with the applicable contract; that all work for
which an Application for Payment is made substantially
conforms to the Contract Documents and any approved changes,
and is in place; and that sufficient funds remain of the
undisbursed Development Financing proceeds to complete the
Project and that all funds previously disbursed have been
applied as per the previous Application for Payment.
b. Waivers of Mechanics' Liens and Materialmen's Liens
executed by all Contractors for all work done and all
materials furnished to the Leased Premises and included in
such current Application for Payment, or evidence reasonably
required by Title to insure over the same by special specific
endorsement, or such other releases of lien pursuant to
bonding or otherwise to prevent such liens from attaching to
the Leased Premises.
c. Waivers of Mechanics' Liens and Materialmen's Liens
executed by all Sub-Contractors and workmen and materialmen
for all work done and all materials furnished to the Leased
Premises and included in the immediately preceding
Application for Payment, or evidence reasonably required by
Title to insure over the same by special specific
endorsement, or such other releases or lien pursuant to
bonding or otherwise to prevent such liens from attaching to
the Leased Premises.
d. Such other supporting evidence, including invoices and
receipts as may be requested by Lessor or LTIC-CDD to
substantiate all payments which are to be made out of the
Disbursement or to substantiate all payments then made in
respect to the Project.
2. INTEREST ADVANCE - If interest has accrued on the Development
Financing and is unpaid or fees are payable to the Lessor
hereunder, Lessor shall be, and hereby is, authorized at any time
to advance to itself from the proceeds of the Development
Financing the total amount of such accrued interest and fees,
whether or not an Application for Payment has been submitted by
the Lessee and the same shall be deemed to be an advance of the
proceeds of the Development Financing under this Agreement in the
same manner and with the same effect as if advanced under the
provisions above. It is understood Lessor may establish an
automatic interest reserve whereby Lessor may withdraw from the
Development Financing account on a regular basis the accrued
interest on the Development Financing and credit the Development
Financing balance with the same.
3. ASSESSMENT AND TAX ADVANCE - As taxes and assessments become
due on the Leased Premises, Lessor shall be, and hereby is,
authorized to advance to itself automatically from the proceeds
of the Development Financing, the total amount of such taxes and
assessments and the same shall be deemed to be an advance of the
proceeds of the Development Financing under this Agreement in the
same manner and with the same effect as if advances under the
provisions above, if not previously paid before due pursuant to
Lessee's obligations under the Lease.
4. DISBURSE UNDER DEVELOPMENT FINANCING DOCUMENT - All sums
advanced and disbursed hereunder shall be disbursed under and
shall be secured by the Development Financing Documents.
5. PAYMENTS TO SUBCONTRACTORS - In its reasonable discretion LTIC-
CDD may make payments directly to any subcontractor or
materialman.
6. RETAINAGE - Each Disbursement shall be limited to an amount
equal to ninety percent (90%) of the value, exclusive of
Contractor's profit and overhead, of the materials and labor
furnished to the Leased Premises and the balance (herein called
the Retainage) shall be retained by Lessor, provided that thirty
(30) days after completion by each subcontractor or materialman
of his subcontract Lessor will disburse to such party, or to the
Contractor on behalf of such party the Retainage withheld from
said party, provided that as a condition to such disbursement the
Lessee and Project Architect and the Inspecting Architect shall
certify to Lessor the date that such Party's subcontract has been
fully and satisfactorily completed and the subcontractor or
materialmen shall have supplied Title with satisfactory final
lien waivers, including final lien waivers for any of its
submaterialmen or sub- contractors and the requirements of any
bonding company issuing the Bonds shall have been fulfilled. Any
Retainage due the Contractor for work performed or materials
furnished by the Contractor and the final balance of Contractor's
profit and overhead shall be disbursed on the Final Disbursement
Date pursuant to Article IX hereof. Contractor's profit and
overhead shall be disbursed based upon and in proportion to the
percentage of completion of the Project, or amounts payable under
the Construction Contract for work actually performed, whichever
is less, as certified by the Project Architect.
ARTICLE IX
FINAL DEVELOPMENT FINANCING BALANCE
Unless and until Lessor and Lessee have entered into a
mutually satisfactory escrow holdback and undertaking agreement
to, inter alia, complete the Improvements and otherwise satisfy
the requirements of this Article IX, at no time and in no event
shall Lessor be obligated to disburse the balance of the proceeds
of the Development Financing, including any Retainage until the
date the following have been satisfied (the "Final Disbursement
Date"):
1. Lessor shall have received reasonably satisfactory evidence of
the final completion of the Improvements in substantial
accordance with the Contract Documents and the Certificate of
Final Completion from the Project Architect accepted by the
Contractor and Lessee.
2. Lessor shall have received satisfactory as-built surveys
reflecting the final location of the Improvements as fully
completed on the Leased Premises in accordance with the Contract
Documents, said survey to be prepared by a registered or licensed
surveyor bearing his registry number, certifying to Lessor as to
the legal description of the Leased Premises and showing all
Improvements located on the Leased Premises and indicating the
street address of the Improvements, absence of any encroachments
on the Leased Premises or from the Leased Premises onto adjacent
land, showing all access points, and showing conformance to all
set back requirements and delineating all utility easements that
are specifically legally described, rights of way and other
matters affecting the Leased Premises, and certifying as to the
total acreage of the land, the exterior dimensions of the
Improvements, and the number of parking spaces, if any, and such
other matters as Lessor may reasonably request.
3. Lessor shall have received a requisite affidavit of the
Lessee, Contractor and Project Architect, and approved by the
Inspecting Architect certifying as to the final cost of the
Improvements.
4. Title shall have been furnished with such final lien waivers
sufficient in the opinion of Title to dissolve any possible
Mechanic's and Materialman's Liens affecting title to the Leased
Premises or Lessee shall have provided a bond or other security
sufficient to remove the lien as an encumbrance upon title to the
Leased Premises and Title shall have issued its endorsements to
the title policy increasing the insured coverage to the full
amount of all sums disbursed under this Development Financing
Agreement.
5. Lessor shall have received evidence that all of the terms,
provisions and conditions on the part of the Lessee to be
performed or caused to be performed hereunder and under the
Lease, including but not limited to obtaining casualty insurance
for the full insurable value of the Improvements, have been
fulfilled to the satisfaction of Lessor.
6. Lessor shall have received a Final Certificate of Occupancy
issued by the appropriate governmental authority covering the
Improvements and a Certificate of Substantial Completion from the
Project Architect indicating that the Improvements as built
comply with all building codes and zoning ordinances, including
any plat requirements or requirements of recorded operating
covenants or agreements affecting the Leased Premises.
7. All remaining uncompleted "punch list" items shall have been
satisfactorily completed.
8. The requirements of all bonding companies, if any, with
respect to release of retainage shall have been met.
9. An amendment to the Lease shall be executed by Lessee and
Lessor setting forth the date the first Lease Year shall end and
the Rent for the balance of the first Lease Year, and evidencing
the satisfaction and termination of this Agreement.
ARTICLE X
EVENTS OF DEFAULT
An "event of default" shall be deemed to have occurred hereunder
and under the Lease, if:
1. DEFAULT UNDER DEVELOPMENT FINANCING DOCUMENTS - Any default or
event of default occurs (which remains uncured after the
expiration of any applicable cure period as may be set forth in
any Development Financing Document) under any of the Development
Financing Documents as defined therein; or
2. FAILURE TO COMPLETE CONSTRUCTION - Lessee shall fail for any
reason, except Lessor's wrongful refusal to fund the Development
Financing pursuant to the terms hereof, to substantially complete
the construction of the Improvements by the Completion Date; or
3. BREACH OF AGREEMENT - Lessee breaches or fails to perform,
observe or meet any covenant or condition of this Agreement,
provided, however, with respect to non-monetary defaults
hereunder, Lessee shall have twenty days after notice from Lessor
to cure such non-monetary default, or if such default (but for
the payment of monies) cannot be cured within twenty days, such
longer time as may be reasonably necessary to effect a cure if
Lessee is diligently pursuing a course of conduct reasonably
designed to cure the default.; or
4. BREACH OF WARRANTY - Any warranties made or agreed to be made
in any of the Development Financing Documents or this Agreement
shall be breached by Lessee or shall prove to be false or
misleading, and the same shall not be cured or made to be true
and correct within the applicable cure periods; or
5. FILING OF LIENS AGAINST THE LEASED PREMISES - Any lien for
labor, material, taxes or otherwise shall be filed against the
Leased Premises and such lien shall not be promptly paid,
released, contested in an appropriate forum, or bonded over to
Lessor's reasonable satisfaction before the lien shall materially
adversely affect Lessor's interest in the Premises; or
6. LITIGATION AGAINST LESSEE - Any suit shall be filed against
Lessee, and is not resolved within 120 days and, which if
adversely determined, could substantially impair the ability of
Lessee to perform each and every one of its obligations under and
by virtue of the Development Financing Documents; or
7. LEVY UPON THE LEASED PREMISES - A levy be made under any
process on the Leased Premises and such levy shall not be
promptly Bonded over prior to the execution of such levy; or
8. TRANSFER OF LEASED PREMISES - Lessee shall without the prior
written consent of Lessor, voluntarily or by operation of law,
sell, transfer, convey or encumber all or any part of its
interest in the Leased Premises or in any of the personalty
located thereon, or used or intended to be used in connection
therewith; or
9. ABANDONMENT - Lessee abandons the project or delays or ceases
work thereon for a period of fifteen consecutive (l5) days, or
delays construction or suffers construction to be delayed for any
period of time for any reason whatsoever so that completion of
Improvements cannot be accomplished in the judgment of Lessor on
or before the Completion Date, subject to force majeure; or
10. BANKRUPTCY - Lessee shall make an assignment for the
benefit of its creditors or shall admit in writing its inability
to pay its debts as they become due or shall file a petition in
bankruptcy or shall be adjudicated a bankrupt or insolvent or
shall file a petition seeking any reorganization, dissolution,
liquidation, arrangement, composition, readjustment, or similar
relief under any present or future bankruptcy or insolvency
statute, law or regulation, or shall file an answer admitting to
or not contesting the material allegations of a petition filed
against it in any such proceedings, or shall not have the same
dismissed or vacated, or shall seek or consent or acquiesce in
the appointment of any trustee, receiver or liquidator of a
material part of its properties, or shall not after the
appointment without the consent or acquiescence of it of a
trustee, receiver, or liquidator of any material part of its
properties have such receiver, liquidator or appointment vacated;
or
11. EXECUTION LEVY - Execution shall have been levied against
the Leased Premises or any lien creditors commence suit to
enforce a judgment lien against the Leased Premises or such
action or suit shall have been brought and shall not be
immediately bonded over and shall continue unstayed and in effect
for a period of more than 120 consecutive days; or
12. ATTACHMENT - Any part of the Lessor's commitment to make
the advances hereunder shall at any time be subject or liable to
attachment or levy at the suit of any creditor of the Lessee or
at the suit of any subcontractor or creditor of the Contractor
and shall remain unstayed prior to the time Lessor shall be
obligated to comply with the same.
ARTICLE XI
REMEDIES OF LESSOR
Lessee hereby agrees that the occurrence of any one or more of
the events of default set out in Article X hereof, shall also
constitute an event of default under each of the Development
Financing Documents, thereby entitling Lessor, after the
expiration of any applicable cure period, at its option, to
proceed to exercise any or all of the following remedies:
1. EXERCISE OF REMEDIES - To exercise any of the various remedies
provided in any of the Development Financing Documents, including
the acceleration of the Put described in Articles XIV hereof;
2. CUMULATIVE RIGHTS - Cumulatively to exercise all other rights,
options and privileges provided by law;
3. CEASE MAKING ADVANCES - To refrain from making any advances
under this Agreement but Lessor may make advances after the
happening of any such event without thereby waiving the right to
refrain from making other further advances or to exercise any of
the other rights Lessor may have.
4. RIGHTS TO ENTER - To require Lessee to vacate the Leased
Premises and permit Lessor (whether prior to the exercise of the
Put or during any period prior to the closing of the sale
pursuant to the Put;
(a) To enter into possession;
(b) To perform or cause to be performed any and all work and
labor necessary to complete the Improvements in accordance
with the Plans and Specifications;
(c) To employ security watchmen to protect the Leased
Premises; and
(d) To disburse that portion of the Development Financing
Proceeds not previously disbursed (including any Retainage)
to the extent necessary to complete the construction of the
Improvements in accordance with the Contract Documents and if
the completion requires a larger sum than the remaining
undisbursed portion of the Development Financing, to disburse
such additional funds, all of which funds so disbursed by
Lessor shall be deemed to have been disbursed to Lessee. For
this purpose, Lessee hereby consents upon an uncured default
by Lessee after the expiration of any applicable notice and
cure period, to the Lessor taking the following actions, or
not, in Lessor's reasonable discretion: to complete the
construction of the Improvements in the name of the Lessee,
and hereby empowers Lessor to take all actions necessary in
connection therewith including but not limited to using any
funds of Lessee including any balance which may be held in
escrow and any funds which may remain unadvanced hereunder
for the purpose of completing the said portion of the
Improvements in the manner called for by the Contract
Documents; to make such additions and changes and corrections
in the Contract Documents which shall be necessary or
desirable to complete the said portion of the Improvements in
substantially the manner contemplated by the Contract
Documents; to employ such contractors, subcontractors,
agents, architects, and inspectors as shall be required for
said purposes; to pay, settle or compromise all existing or
future bills and claims which are or may be liens against
said Leased Premises, or may be necessary or desirable for
the completion of the said portion of the Improvements or the
clearance of title to the Leased Premises; to execute all
applications and certificates in the name of Lessee which may
be required by any construction contract and to do any and
every act with respect to the construction of the said
portion of the Improvements which Lessee may do in its own
behalf. Lessor shall also have power to prosecute and defend
all actions and proceedings in connection with the
construction of the said portion of the Improvements and to
take such action and require such performance as it deems
necessary. In accordance therewith, Lessee hereby assigns
and quitclaims unto Lessor all sums to be advanced hereunder
including Retainage. Any funds so disbursed or fees or
charges so incurred shall be included in any amount necessary
for the Lessee to pay pursuant to the Put.
(e) To discontinue making advances hereunder to the Lessee
and to terminate Lessor's obligations under this Agreement.
5. RIGHTS NON CUMULATIVE - No right or remedy by this Agreement
or by any Development Financing Document or instrument delivered
by the Lessee pursuant hereto, conferred upon or reserved to the
Lessor shall be or is intended to be exclusive of any other right
or remedy and each and every right and remedy shall be cumulative
and in addition to any other right or remedy or now or hereafter
arising at a law or in equity or by statute. Except as Lessor
may hereafter otherwise agree in writing, no waiver by Lessor or
any breach by or default of Lessee of any of its obligations,
agreements, or covenants under this Agreement shall be deemed to
be a waiver of any subsequent breach of the same or any other
obligation, agreement or covenant, nor shall any forbearance by
Lessor to seek a remedy for such breach be deemed a waiver of its
rights and remedies with respect to such a breach, nor shall
Lessor be deemed to have waived any of its rights and remedies
unless it be in writing and executed with the same formality as
this Agreement.
6. EXPENSES - The Development Financing and this Agreement and
the performance by the Lessor or Lessee of their obligations
hereunder shall be without cost and expense to the Lessor, all of
which costs and expenses the Lessee agrees to pay and hold Lessor
harmless of and payment of which shall be secured by the
Development Financing Documents. Specifically, Lessee agrees to
pay all title charges, surveyor's fees, appraisals, loan fees and
attorney's fees and costs and the like incurred in connection
with this Agreement.
ARTICLE XII
GENERAL CONDITIONS AND MISCELLANEOUS
The following conditions shall be applicable throughout the term
of this Agreement:
1. RIGHTS OF THIRD PARTIES - All conditions of the obligations of
Lessor hereunder, including the obligation to make disbursements
are imposed solely and exclusively for the benefit of Lessee, and
no other person shall have standing to require satisfaction of
such conditions in accordance with their terms or be entitled to
assume that Lessor will refuse to make advances in the absence of
strict compliance with any or all thereof, and no other person
shall, under any circumstances, be deemed to be a beneficiary of
such conditions, any and all of which may be freely waived in
whole or in part by Lessor at any time if in its sole discretion
it deems it desirable to do so. In particular, Lessor makes no
representations and assumes no duties or obligations as to third
parties concerning the quality of the construction of the
Improvements or the absence therefrom of defects. In this
connection, Lessee agrees to and shall indemnify Lessor from any
liability, claims or losses resulting from the disbursement of
the Development Financing proceeds or from the condition of the
Leased Premises whether related to the quality of construction or
otherwise and whether arising during or after the term of the
Development Financing made by Lessor to Lessee in connection
therewith, except for Lessor's gross negligence or willful
misconduct. This provision shall survive the termination of this
Agreement and shall continue in full force and effect so long as
the possibility of any such liability, claims or losses exists.
2. EVIDENCE OF SATISFACTION OF CONDITIONS - Any condition of this
Agreement which requires the submission of evidence of the
existence or non- existence of a specified fact or facts implies
as a condition the existence or non- existence, as the case may
be, of such fact or facts, and Lessor shall, at all times, be
free independently to establish to its reasonable satisfaction
such existence or non-existence.
3. ASSIGNMENT - Lessee may not assign this Development Financing
Agreement or any of its rights or obligations hereunder without
the prior written consent of Lessor.
4. SUCCESSORS AND ASSIGNS - Whenever in this Agreement one of the
parties hereto is named or referred to, the heirs, legal
representatives, successors and assigns of such parties shall be
included and all covenants and agreements contained in this
Agreement by or on behalf of the Lessee or by or on behalf of the
Lessor shall bind and inure to the benefit of their respective
heirs, legal representatives, successors and assigns, whether so
expressed or not.
5. HEADINGS - The headings of the sections, paragraphs and
subdivisions of this Agreement are for the convenience of
reference only, and are not to be considered a part hereof and
shall not limit or otherwise affect any of the terms hereof.
6. INVALID PROVISIONS TO AFFECT NO OTHERS - If fulfillment of any
provision hereof, or any transaction related thereto at the time
performance of any such provision shall be due, shall involve
transcending the limit of validity prescribed by law, then, ipso
facto, the obligation to be fulfilled shall be reduced to the
limit of such validity; and such clause or provision shall be
deemed invalid as though not herein contained, and the remainder
of this Agreement shall remain operative in full force and
effect.
7. NUMBER AND GENDER - Whenever the singular or plural number,
masculine or feminine or neuter gender is used herein, it shall
equally include the other.
8. AMENDMENTS - Neither this Agreement nor any provision hereof
may be changed, waived, discharged or terminated orally, but only
by an instrument in writing signed by the party against whom
enforcement of the change, waiver, discharge or termination is
sought.
9. NOTICES - Any notice which any party hereto may desire or may
be required to give to any of the parties shall be in writing and
the mailing thereof by certified mail, or equivalent, to the
respective parties' addresses set forth hereinabove or to such
other place such party may by notice in writing designate as its
address shall constitute service of notice hereunder.
10. GOVERNING LAW - This Development Financing Agreement is
made and executed pursuant to and is intended to be governed by
the laws of the State where the Leased Premises are located.
11. FORCE MAJEURE - Anything in this Agreement to the contrary
notwithstanding, Lessee shall not be deemed in default with
respect to the performance of any of the terms, provisions,
covenants, and conditions of this Agreement (except for the
payment of all other monetary sums payable hereunder, to which
the provisions of this Section shall not apply), if the same
shall be due to any strike, lockout, civil commotion, warlike
operations, invasion, rebellion, hostilities, sabotage,
governmental regulations or controls, impracticability of
obtaining any materials or labor (except due to the payment of
monies), shortage or unavailability of a source of energy or
utility service, Act of God, casualty, adverse weather
conditions, or any cause beyond the reasonable control of Lessee
(except due to the payment of monies). Provided, however, in
order to invoke the extension of the Completion Date afforded by
this section, Lessee shall notify Lessor in writing within five
days of the occurrence of such force majeure, and in any event
the Completion Date shall be extended as a result of such
occurrence no more than reasonably necessary and in no event no
more than 90 days.
ARTICLE XIII
DAMAGE, DESTRUCTION, CONDEMNATION, USE OF INSURANCE PROCEEDS
1. DAMAGE OR DESTRUCTION OF THE LEASED PREMISES. Lessee
will give the Lessor prompt notice of any damage to or
destruction of the Leased Premises and in case of loss covered by
policies of insurance the Lessor (whether before or after the
exercise of the Put if Lessee be in default hereof) is hereby
authorized at its option to settle and adjust any claim arising
out of such policies and collect and receipt for the proceeds
payable therefrom, provided, that the Lessee may itself adjust
and collect for any losses arising out of a single occurrence
aggregating not in excess of $100,000.00. Any expense incurred
by the Lessor in the adjustment and collection of insurance
proceeds (including the cost of any independent appraisal of the
loss or damage on behalf of Lessor) shall be reimbursed to the
Lessor first out of any proceeds. Subject to paragraph 4 hereof,
the proceeds or any part thereof shall be applied to reduction of
the Put Price, which Put may then be exercised by Lessor, without
the application of any prepayment premium, or to the restoration
or repair of the Leased Premises, the choice of application to be
solely at the discretion of Lessor.
2. CONDEMNATION. Lessee will give the Lessor prompt notice
of any action, actual or threatened, in condemnation or eminent
domain affecting the Leased Premises and hereby assigns,
transfers, and sets over to the Lessor the entire proceeds of any
award or claim for damages for all or any part of the Leased
Premises taken or damaged under the power of eminent domain or
condemnation, the Lessor being hereby authorized to intervene in
any such action and to collect and receive from the condemning
authorities and give proper receipts and acquittances for such
proceeds. Lessee will not enter into any agreements with the
condemning authority permitting or consenting to the taking of
the Leased Premises unless prior written consent of Lessor is
obtained. Any expenses incurred by the Lessor in intervening in
such action or collecting such proceeds shall be reimbursed to
the Lessor first out of the proceeds. Subject to paragraph 4
hereof, the proceeds or any part thereof shall be applied to
reduction of the Put Price, which Put may then be exercised by
Lessor, without the application of any prepayment premium, or to
the restoration or repair of the Leased Premises, the choice of
application to be solely at the discretion of Lessor.
3. DISBURSEMENT OF INSURANCE AND CONDEMNATION PROCEEDS. Any
restoration or repair shall be done under the supervision of an
architect acceptable to Lessor and pursuant to plans and
specifications approved by the Lessor. Subject to paragraph 4
below, in any case where Lessor may elect to apply the proceeds
to repair or restoration or permit the Lessee to so apply the
proceeds they shall be held by Lessor for such purposes and will
from time to time be disbursed by Lessor to defray the costs of
such restoration or repair under such safeguards and controls as
Lessor may reasonably require to assure completion in accordance
with the approved plans and specifications and free of liens or
claims, to be disbursed as if such disbursements were
disbursements of Development Financing. Lessee shall on demand
deposit with Lessor any sums necessary to make up any deficits
between the actual cost of the work and the proceeds and provide
such lien waivers and completion bonds as Lessor may reasonably
require. Any surplus which may remain after payment of all costs
of restoration or repair shall be applied against the rent then
most remotely to be paid, whether due or not, without application
of any prepayment premium or credit.
4. LESSOR TO MAKE PROCEEDS AVAILABLE. In the event of
insured damage to the improvements or in the event of a taking by
condemnation of only a portion of the improvements or land area
of the Leased Premises, provided, the Completion Date need not be
extended more than 90 days, the appraised value of the Leased
Premises after such restoration or repair shall not have been
reduced, and provided further, no event of default exists under
this Agreement after the expiration of any applicable cure
periods and Lessee is diligently pursuing a course of conduct
reasonably designed to cure such default, and the Lessee
certifies to Lessor their intention to remain in possession of
the Leased Premises without any abatement or adjustment of rental
payments, the Lessor agrees to make the proceeds available to the
restoration or repair of the improvements on the Leased Premises
in accordance with the provisions of paragraph 3 hereof.
ARTICLE XIV
MANDATORY PUT UPON DEFAULT
Should Lessee commit an event of Default under this Agreement
or any Development Financing Document (after the expiration of
any applicable notice and cure period) ("Uncured Default"),
Lessor shall have the following rights:
Upon an Uncured Default, or damage or destruction or
condemnation of the Leased Premises not addressed by paragraph
XIII (4), if Lessor elects to exercise the following option,
Lessee shall purchase the Leased Premises from Lessor subject to
the following terms and conditions:
A. The purchase price at which Lessor shall sell the Leased
Premises to Lessee, shall be the total amount of Initial
Disbursed Funds disbursed by Lessor to acquire the
Leased Premises at the Closing Date (as defined in the
Commitment), plus the total amount of funds disbursed
pursuant to this Agreement, plus all accrued interest
and incurred expenses of Lessor fundable pursuant to
this Agreement, plus all reasonable costs of collection
and enforcement of the terms hereof.
B. At such time as Lessor shall elect to sell the Leased
Premises, Lessor shall give Lessee written notice of its
intent to exercise its option to sell the Leased
Premises to Lessee, including in such notice Lessor's
calculation of the Purchase Price through the actual
closing of the sale of the Leased Premises to Lessee
pursuant to the terms hereof (the "Sale Date"), which
shall be sixty days from such notice by Lessor. Lessee
shall on or before the Sale Date deliver the purchase
price as set forth in subparagraph (A) of this Article
to Lessor. Upon such delivery, which shall be preceded
by ten (10) days notice to Lessor, Lessor shall deliver
to Lessee a warranty deed and appropriate affidavits
evidencing that Lessor transfers the Leased Premises to
Lessee subject to restrictions, easements or other
encumbrances upon title existing as of the date of
delivery, if any, except to the extent, if any, placed
of record or caused by Lessor. The purchase price to be
paid to Lessor shall be a net amount. All expenses in
connection with the transfer of the Leased Premises,
including, but not limited to appraisal fees, title
insurance, recording fees, documentary stamps,
conveyance tax, title evidence, and all other closing
costs, shall be paid by the Lessee. The purchase price
shall be paid by Lessee in cash to Lessor concurrently
with the conveyance of the Leased Premises by the Lessor
to the Lessee. If Lessor elects to sell the Leased
Premises to Lessee pursuant to the terms hereof, the
Leased Premises shall be conveyed by the Lessor to the
Lessee "As Is".
If Lessee shall fail to pay the Purchase Price on or before
the Sale Date, Lessor may terminate the Lease, and sell the
Leased Premises to any third party purchaser. Lessor may then
send Lessee notice of the shortfall (the "Deficiency"), if any,
between the amount of the net proceeds received by Lessor in such
sale, and the total amount of Initial Disbursed Funds disbursed
by Lessor to acquire the Parcel at the Closing Date (as defined
in the Commitment), plus the total amount of funds disbursed
pursuant to this Agreement, plus all accrued interest and
incurred expenses of Lessor fundable pursuant to this Agreement,
plus all reasonable costs of collection and enforcement of the
terms hereof. Lessee shall immediately upon receipt of such
notice of Deficiency remit the amount of the Deficiency in good
funds to Lessor.
Lessor's rights under this Mandatory Put shall expire on the
Final Disbursement Date when the amendment to the Lease has been
executed by all parties as set forth in Article IX hereof.
ARTICLE XV
RENT, INTEREST, AND RENTAL MODIFICATION DATE
1. Rent shall be payable by Lessee and calculated as follows, on
the funds advanced by Lessor on the Closing Date for the purchase
of the land and related closing costs (the "Initial Disbursed
Funds"): Rent shall accrue in the amount of $11,390 per month
absent an uncured Default by Lessee; absent an uncured Default,
accrued rent during the period of construction of the
Improvements prior to the Rental Modification Date shall not be
payable until the Final Disbursement Date. Upon the occurrence
of an uncured Default, all accrued rent shall be immediately due
and payable.
On the Rental Modification Date, if not otherwise in default
hereunder, Lessee shall begin paying Rent by the first of each
month (prorata for the balance of any partial month in which the
Rental Modification Date occurs, payable with the first such
adjusted Rent payable on the first day of the first full month
following the Rental Modification Date) in the amount of $13,065
per month out of pocket. On the Final Disbursement Date, absent
an Uncured Default, Rent shall be adjusted and documented by the
lease amendment contemplated in ARTICLE IX hereof and paid to
Lessor as described in ARTICLE F. of the Commitment.
2. Disbursed proceeds of the Development Financing shall
accrue interest at a rate of Eight and one-half percent (8.5%)
per annum, which interest shall accrue unpaid unless advanced by
Lessor to itself, or Lessee shall default hereunder, which
default shall remain uncured after the expiration of any
applicable notice and cure period. However, one hundred and
fifty days (150) from the date hereof, (the "Rental Modification
Date"), Lessee shall begin making monthly payments of
subsequently accruing interest at the rate of 9.75% per annum out
of pocket ("Out of Pocket Invoiced Interest") within 5 days after
invoice from Lessor.
3. Upon the occurrence of an event of default which remains
uncured after the expiration of applicable notice and cure
periods, disbursed proceeds of the Development Financing shall
accrue interest at a rate of Fifteen Percent (15.0%) per annum,
or the highest rate allowed by law, whichever is less, and the
rental rate on the Initial Disbursed funds shall increase to
Fifteen Percent (15.0%) per annum, or the highest rental rate
allowed by law, whichever is less.
ARTICLE XVI
COUNTERPART EXECUTION
Counterpart Execution. This Agreement may be executed in
multiple counterparts, each of which shall be deemed an original
and all of which shall constitute one and the same instrument.
IN WITNESS WHEREOF, Lessee and Lessor have hereunto caused
these presents to be executed on the date first above written.
Razzoo's, Inc., a Texas corporation
By: /s/ X Xxxxxx
Its: Director of Finacne & Accounting
[Lessor's Signature appears on following page.]
AEI Net Lease Income & Growth Fund XIX Limited Partnership
By: AEI Fund Management XIX, Inc.
By:/s/ Xxxxxx X Xxxxxxx
Xxxxxx X. Xxxxxxx, President
AEI Real Estate Fund XVIII Limited Partnership
By: AEI Fund Management XVIII, Inc.
By:/s/ Xxxxxx X Xxxxxxx
Xxxxxx X. Xxxxxxx, President
AEI Private Net Lease Millennium Fund Limited Partnership
By: AEI Fund Management XVIII, Inc.
By:/s/ Xxxxxx X Xxxxxxx
Xxxxxx X. Xxxxxxx, President
AEI Income & Growth Fund 23 LLC
By: AEI Fund Management XXI, Inc.
By: /s/ Xxxxxx X Xxxxxxx
Xxxxxx X. Xxxxxxx, President
EXHIBIT "A"
All that tract or parcel of land lying and being located Land Xxx
000, 0xx Xxxxxxxx, 0xx Xxxxxxx, Xxxx of Alpharetta, Xxxxxx
County, Georgia and being more particularly described as follows:
BEGINNING at a point located at the Southwest end of a miter at
the intersection of the East right of way (R/W) line of Xxxxxx
Bridge Road (R/W varies) and the Southeast R/W line of North
Point Parkway (130' R/W): thence along said miter North 33 26'
45" East, a distance of 58.73 feet to a point on the Southeast
R/W line of North Paint Parkway; thence following said R/w line
North 84 09' 13" East, a distance of 90.00 feet to a point;
thence 152.49 feet along a curve to the left, said curve having a
chord of North 78 33' 41" east 152.25 feet and a radius of 781.20
feet to a point; thence 213.48 feet along a curve to the left,
said curve having a chord of North 65 08' 28" East 212.82 feet
and a radius of 781.20 feet to a 1/2" rebar set and the TRUE POINT
OF BEGINNING; thence continuing along said R/W line 26.70 feet
along a curve to the left, said curve having a chord of North 56
79'58" East 26.70 feet and a radius of 781.20 to a po9int; thence
North 55 21' 13" East, a distance of 320.00 feet to a point ;
thence 14.34 feet along a curve to the right, said curve having a
chord of North 55 39' 04" East 14.34 feet and a radius of 651.20
feet to a 1/2 " rebar set at the Northwest end of a miter at the
intersection of said R/W line and the northwest R/W line of
Xxxxxxx Xxxx (R/W varies)" thence along said miter South 67 34'
15" East, a distance of 103.65 feet to a 1/2" rebar set on the
northwest R/W line of Xxxxxxx Xxxx; thence following said R/W
line South 20 00' 59" East, a distance of 51.07 feet to a point;
thence 268.67 feet along a curve to the right, said curve having
a chord of South 15 04' 23" West 263.88 feet and a radius of
409.50 feet to a po9int; thence South 34 52' 09" West, a distance
of 175.47 feet to a concrete nail set; thence leaving said R/W
line North 55 07' 51" West , a distance of 77.67 feet to a 1/2"
rebar set; thence North 36 20' 19" West, a distance of 292.87
feet to the TRUE POINT OF BEGINNING, Said tract contains 2.593
acres or 112962 square feet.
TOGETHER WITH THE RIGHTS OF EGRESS AND INGRESS AS SET FORTH IN
THAT CERTAIN INTERPARCEL ACCESS EASEMENT CONTAINED IN DB 24701,
PAGE 280, RECORDS OF XXXXXX COUNTY, GA.
RAZZOO'S
ALPHARETTA, GEORGIA
PRELIMINARY PROJECT COST BUDGET
CREATED: MAY 19, 2000
LAND AND HARD COSTS:
Land Acquisition Cost $1,600,000.00
Building/General Construction 1,575,982.00
Sitework 304,239.00
Construction Contingency-10.0% 175,000.00
SUBTOTAL HARD COSTS $3,655,221.00
SOFT COSTS:
Landscaping - vendor contract 100,000.00
Survey 1,500.00
Architect 64,140.00
Engineer-civil 11,500.00
Site Engineering 0
Phase I Environmental 0
Permits & Fees 4,500.00
Architect Development Services 10,000.00
Builders Risk Insurance 1,600.00
Soils Report/Materials Tests 0
Title Insurance & Closing Costs
(Construction and S/L) 15,000.00
Development Interest 38,680.00
Attorney's Fees-Borrower 5,000.00
Attorney's Fees - AEI 12,000.00
AEI 1% Reimbursement 37,900.00
AEI State Qualification Fees 1,000.00
Appraisal 3,500.00
AEI Credit Report Fees (Promesa) 600.00
Miscellaneous 16,175.00
SUBTOTAL SOFT COSTS $ 316,779.00
TOTAL PROJECT COST $3,972,000.00
RAZZOO'S EQUITY CONSTRIBUTION ($142,000.00)
AEI TOTAL PROJECT COST $3,830,000.00
