EXHIBIT 10.2
AGREEMENT
BETWEEN
LIDO CASINO RESORT, LLC
AND
GGP LIMITED PARTNERSHIP
DATED: AS OF APRIL 12, 2004
TABLE OF CONTENTS
Page
----
ARTICLE 1 CERTAIN DEFINITIONS.......................................... 2
ARTICLE 2 DESIGN OF MALL IMPROVEMENTS.................................. 10
ARTICLE 0 XXXXXXXXXXXX XX XXXX IMPROVEMENTS............................ 14
ARTICLE 4 DESIGN OF BUILD-OUT OF PHASE II MALL......................... 22
ARTICLE 5 CONSTRUCTION OF BUILD-OUT.................................... 23
ARTICLE 6 ACCESS TO PHASE II LAND; RELATED MATTERS..................... 26
ARTICLE 7 TIMING FOR DESIGN AND CONSTRUCTION........................... 27
ARTICLE 8 AMENDED REA AND XXXXX........................................ 29
ARTICLE 9 CONSULTATION; DISPUTE RESOLUTION............................. 30
ARTICLE 10 MALL II BUYER CONDITIONS.................................... 33
ARTICLE 11 DEVELOPER CONDITIONS........................................ 35
ARTICLE 12 WAIVER OF CONDITIONS........................................ 36
ARTICLE 13 CLOSING..................................................... 37
ARTICLE 14 CLOSING DELIVERIES; RELATED MATTERS......................... 37
ARTICLE 15 REPRESENTATIONS AND WARRANTIES OF
DEVELOPER; CERTAIN AGREEMENTS....................................... 39
ARTICLE 16 REPRESENTATIONS AND WARRANTIES OF MALL II
BUYER; CERTAIN AGREEMENTS........................................... 46
ARTICLE 17 TRANSACTION EXPENSES; TITLE INSURANCE....................... 49
ARTICLE 18 DAMAGE OR DESTRUCTION; CONDEMNATION......................... 50
ARTICLE 19 REMOVAL OF TITLE DEFECTS.................................... 51
ARTICLE 20 CLOSING AND OTHER PAYMENTS.................................. 52
ARTICLE 21 PRE-CLOSING REMEDIES........................................ 56
ARTICLE 22 POST-CLOSING REMEDIES....................................... 58
ii
Page
----
ARTICLE 23 NOTICES..................................................... 58
ARTICLE 24 MISCELLANEOUS............................................... 59
Schedules and Exhibits
Schedule "1" - Phase II Land
Schedule "2" - Leasehold Airspace
Schedule "3" - Phase IA Airspace
Schedule "4" - Continuing Service Contracts
Schedule "5" - Permitted Encumbrances
Schedule "6" - Consents and Exceptions to Representations of the Parties
Schedule "7" - Miscellaneous Closing Deliveries
Schedule "8" - Authorized Representatives; Notice Addresses
Schedule "9" - Construction Safety & Health Manual
Schedule "10" - Organizational Representations of Developer and Mall II Buyer
Schedule "11" - Definition of Substantial Completion
Schedule "12" - REA
Schedule "13" - Mall II Buyer Legal Rates
Schedule "14" - Tenant Handbook
Schedule "15" - Cost Sharing Allocations
Schedule "16" - Master Lease Agreement
Schedule "17" - Intentionally Omitted
Schedule "18" - Leases
Schedule "19" - Gaming Provisions for Leases
Schedule "20" - Work Continuation Agreement
Exhibit A - Standards Document, attaching Leasing Plans and Character
Sketches
Exhibit B - Developer's Representation Certificate
iii
Index of Defined Terms
Term Section
---- -------
Adjustment Payment.......................................... 20.2
Affiliate................................................... 1.1
Agreement................................................... 1.1
Amended REA................................................. 8.1
amended..................................................... 1.2
amendment................................................... 1.2
Anticipated Completion Date................................. 3.8
As-Built Floor Area......................................... 2.3
Assignment.................................................. 14.1
at Developer's expense...................................... 1.2
at Mall II Buyer's expense.................................. 1.2
Authorized Representative................................... 1.1
Back-Of-House Areas......................................... Ex. A
Basket...................................................... 15.12
Building.................................................... 1.1
Build-Out................................................... 1.1
Build-Out Notice............................................ 3.7
Build-Out Work.............................................. 1.1
Business Day................................................ 1.1
Buyer Delay................................................. 1.1
Buyer Liquidated Damages Amount............................. 7.1
Buyer's Proposed Final Checklist............................ 3.8
by hand..................................................... 23
C of O...................................................... 3.7
Cap......................................................... 15.12
Cap Rate.................................................... 20.2
Casino Shops................................................ WHEREAS Clause E
CE Warranty Work............................................ 3.4
Character Sketches.......................................... Ex. A
Close-Out................................................... 3.4
Closing..................................................... 1.1
Closing Date................................................ 13.1
Closing Instruments......................................... 1.1
Closing Payment............................................. 20.2
Common Area................................................. Ex. A
Common Area Plans........................................... 2.1
Common Elements............................................. 1.1
Competitor.................................................. 1.1
Condemnation................................................ 18.1
Construction Delay.......................................... 1.1
Construction Safety & Health Manual......................... 5.4
Consultant.................................................. 1.1
Contractor Warranty......................................... 3.4
2
2
Control...................................................... 1.1
XXXXX........................................................ 8.2
CPI.......................................................... Sch. 15
CPI Adjustment............................................... Sch. 15
CPI Increase................................................. Sch. 15
day.......................................................... 1.2
Defective Work............................................... 3.4
delay........................................................ 1.2
Demising Walls............................................... 2.2
Developer.................................................... Preamble
Developer Delay.............................................. 1.1
Developer Indemnitees........................................ 5.2
Developer Liquidated Damages Amount.......................... 21.2
Developer's Architect........................................ 1.1
Developer's Representation Certificate....................... 15.12
Developer's Warranty......................................... 3.4
Development.................................................. 1.1
Direct Costs................................................. 5.4
Disputing Parties............................................ 9.2
Earn-Out Date................................................ 20.2
Earn-Out Payment............................................. 20.2
Encumbrance.................................................. 1.1
Exceptions Notice............................................ 3.8
Exclusive Mall Equipment..................................... 1.1
Fee Mall Space............................................... 1.1
Fees and Costs............................................... 1.1
Field Changes................................................ 3.3
Final Construction Drawings and Specs........................ 2.1
Final Date................................................... 20.3
Final Demising Wall Plan..................................... 2.2
First-Class.................................................. 1.1
Floor Area................................................... 1.1
Force Majeure................................................ 1.1
Gaming Authority............................................. 1.1
Gaming Licenses.............................................. 1.1
Government Authorities....................................... 1.1
H/C I Owner.................................................. 1.1
H/C II Space................................................. 1.1
Hazardous Material(s)........................................ 1.1
Impositions.................................................. 1.1
include...................................................... 1.2
including.................................................... 1.2
Independent Expert........................................... 9.4
Initial Construction Drawings and Specs...................... 2.1
Initial Demising Wall Plan................................... 2.2
Initial Plans................................................ 2.1
3
Initial Market Disruption Date............................... 20.2
Inspection Period............................................ 3.8
Institutional Investor....................................... 1.1
Interest Rate................................................ 1.1
Interim Liquidated Damages................................... 7.1
Interim Payment Date(s)...................................... 20.2
Interim Substantial Completion Notices....................... 3.8
knowledge.................................................... 15.10
Landlord Build-Out........................................... 1.1
Landlord Build-Out Work...................................... 1.1
law.......................................................... 1.2
laws......................................................... 1.2
Lease........................................................ 1.1
Leasing Plans................................................ Ex. A
Lease Damages................................................ 7.1
Leasehold.................................................... WHEREAS Clause B
Leasehold Airspace........................................... WHEREAS Clause B
Leasehold Mall Space......................................... 1.1
Leasing Costs................................................ 1.1
Legal Proceeding............................................. 1.1
Legal Requirements........................................... 1.1
Major Event.................................................. 18.1
Mall Equipment............................................... 1.1
Mall Opening Date............................................ 7.2
Mall I Buyer................................................. 1.1
Mall I Call Price............................................ 21.2
Mall I LLC................................................... 1.1
Mall II Buyer................................................ Preamble
Mall II Buyer Monthly Statement.............................. 3.2
Mall II Buyer Site Representative............................ 9.1
Mall II LLC.................................................. WHEREAS Clause D
Mall II Unit Warranty Work................................... 3.4
Mall II Unit................................................. 1.1
Mall Improvements............................................ 1.1
Mall Indemnitees............................................. 3.5
Mall Space................................................... WHEREAS Clause D
Market Disruption Event...................................... 20.2
Master Lease Agreement....................................... WHEREAS Clause E
McCarran Passengers.......................................... 20.2
Membership Interests......................................... WHEREAS Clause G
month........................................................ 1.2
Mortgage..................................................... 1.1
No-Offset Clause............................................. 3.4
notice....................................................... 1.2
Open for Business............................................ 7.2
Opening Date................................................. 7.2
4
Outside Substantial Completion Date........................... 7.1
Palazzo Casino Resort......................................... WHEREAS Clause C
party......................................................... 1.2
Permitted Encumbrances........................................ 1.1
Person........................................................ 1.1
Phase I Hotel/Casino.......................................... 1.1
Phase I Mall.................................................. 1.1
Phase I Mall Sale Agreement................................... 1.1
Phase IA Airspace............................................. 1.1
Phase IA Conference Center.................................... 1.1
Phase II Automobile Parking Area.............................. 1.1
Phase II Hotel/Casino......................................... 1.1
Phase II Land................................................. WHEREAS Clause A
Phase II Mall Documents....................................... 1.1
Phase II Mall................................................. WHEREAS Clause E
Projected Fee Floor Area...................................... 2.3
Proposed Final Checklist...................................... 3.8
Projected Leasehold Floor Area................................ 2.3
Proposed Lease................................................ 16.4
Proposed Tenant............................................... 16.4
Punch List Items.............................................. Sch. 11
Punch List Work............................................... 3.8
REA........................................................... WHEREAS Clause J
Recalculated Earn-Out......................................... 20.3
recorded...................................................... 1.2
Required Fee Floor Area....................................... 2.3
Required Leasehold Floor Area................................. 2.3
Required Mall Improvement Permits............................. 1.1
Retail and Restaurant Tenant Areas............................ Ex. A
Service Contract.............................................. 1.1
Shared Mall Expenses.......................................... 8.2
Site Logistics Procedures..................................... 5.4
SNDA.......................................................... 10.1
Standards Document............................................ 2.1
State......................................................... 1.1
subject to the terms of this Agreement........................ 1.2
Substantial Completion........................................ Sch. 12
Tenant........................................................ 1.1
Tenant Build-Out.............................................. 1.1
Tenant Build-Out Work......................................... 1.1
Tenant Handbook............................................... 5.1
Tenant Payments............................................... 16.3
Tenant Space.................................................. 1.1
Title Defect.................................................. 19.1
Title Insurance Commitment.................................... 1.1
Title Insurer(s).............................................. 1.1
5
Tsunami................................................... 10.1
Unit Owner................................................ 1.1
Use and Occupancy......................................... 1.1
utilities................................................. 1.2
utility................................................... 1.2
Venetian Casino Resort.................................... WHEREAS Clause J
AGREEMENT
This AGREEMENT made as of April 12, 2004 by and between LIDO CASINO
RESORT, LLC, a Nevada limited liability company with an office at 3355 Las Vegas
Boulevard South, Room 1C, Xxx Xxxxx, XX 00000 ("Developer") and GGP LIMITED
PARTNERSHIP, a Delaware limited partnership with an address at 000 Xxxxx Xxxxxx
Xxxxx, Xxxxxxx, Xxxxxxxx 00000 ("Mall II Buyer").
Introductory Statement
A. WHEREAS, Developer is the owner in fee simple of that certain
parcel of land located in the County of Xxxxx, State of Nevada as the same is
more particularly described on Schedule "1" attached hereto and made a part
hereof (the "Phase II Land"); and
B. WHEREAS, pursuant to that certain Commercial Lease dated as of
March 1, 2004, by and between CAP II - Buccaneer, LLC, as landlord, and
Developer, as tenant, Developer is the holder of a leasehold interest (the
"Leasehold") in and to that certain airspace described on Schedule "2" attached
hereto and made a part hereof (the "Leasehold Airspace"); and
C. WHEREAS, Developer intends to construct and operate a mixed use
development on the Phase II Land and within the Leasehold Airspace (such mixed
use development, including, without limitation, a hotel, casino, restaurant and
retail facility to be located on the Phase II Land and the Phase II Automobile
Parking Area, but excluding the Phase IA Airspace, the Phase IA Conference
Center and any other buildings and improvements located within the Phase IA
Airspace, the "Palazzo Casino Resort"); and
D. WHEREAS, prior to Closing, Developer will assign and convey a
portion of the Palazzo Casino Resort consisting of a proposed mall with retail
shops and restaurants, together with those certain rights in the Common Elements
as are described herein, located in the airspace above the Phase II Land and/or
portions of the Leasehold Airspace (the "Mall Space") to an entity created for
the exclusive purpose of owning the mall to be constructed in the Mall Space and
being the lessee under the Master Lease Agreement ("Mall II LLC"); and
E. WHEREAS, Developer intends to enter into that certain Casino
Level Restaurant/Retail Master Lease Agreement by and between Developer and Mall
II LLC (the "Master Lease Agreement") in substantially the form attached hereto
as Schedule "16" whereby Developer will lease to Mall II LLC certain retail
stores in the Phase II Hotel/Casino (the "Casino Shops" and, together with the
Mall Space, the "Phase II Mall"); and
F. WHEREAS, Developer will design and construct, for the
consideration described in Article 20 herein, the Mall Improvements, including
the Common Elements and the Demising Walls for Tenant Spaces located in the
Phase II
2
Mall simultaneously with the construction of the Palazzo Casino Resort pursuant
to the terms of this Agreement; and
G. WHEREAS, upon the Closing Date, as defined herein, Developer will
sell and Mall II Buyer will purchase all of the limited liability company
interests in Mall II LLC (the "Membership Interests") on the terms and
conditions set forth herein; and
H. WHEREAS, Mall II Buyer and Developer will jointly implement, at
Developer's expense, the Build-Out of tenant spaces located in the Phase II
Mall, as described below; and
I. WHEREAS, the Standards Document governing construction of the
Mall Improvements is attached hereto as Exhibit "A" and made a part hereof, the
Phase II Mall is depicted with greater particularity as the shaded areas on the
Leasing Plans attached to the Standards Document attached to this Agreement as
Exhibit "A;" and
J. WHEREAS, that certain Second Amended and Restated Reciprocal
Easement Agreement to be entered into by and among H/C I Owner, Developer, Grand
Canal Shops II, LLC and Interface Group-Nevada, Inc. (the "REA") governs certain
aspects of the construction of the Palazzo Casino Resort and sets forth the
agreements of the parties thereto regarding the operation of the Palazzo Casino
Resort and that certain Venetian-themed complex containing a hotel and casino
and restaurant and retail space located adjacent to the Palazzo Casino Resort
(the "Venetian Casino Resort") and provides for the further amendment and/or
restatement of the REA to set forth additional agreements regarding the
admission of Mall II LLC as a party to the REA; and
K. WHEREAS, The Palazzo Casino Resort and the Phase II Mall are each
intended to be First-Class projects of their type and to make optimal use of the
Phase II Land and the Leasehold Airspace, which is unique in its location on Las
Vegas Boulevard adjacent to the Venetian Casino Resort.
NOW, THEREFORE, in consideration of the promises and obligations of
Developer and Mall II Buyer set forth in this Agreement, subject to the terms of
this Agreement and intending to be legally bound hereby, the parties agree as
follows:
ARTICLE 1
CERTAIN DEFINITIONS
1.1 The following words and phrases have the following meanings in
this Agreement:
"Affiliate" when used with respect to a Person, shall mean a Person
that directly, or indirectly through one or more intermediaries, controls or is
controlled by, or is under common control with, the Person specified. The term
"control" (including the
3
terms controlling, controlled by and under common control with), as used herein,
means the possession, directly or indirectly, of the power to direct or cause
the direction of the management and policies of a Person, whether through (i)
the ownership of fifty percent (50%) or more of the voting rights with respect
to such Person, or (ii) ownership in such Person of thirty-three and one-third
percent (33 1/3%) or more of all equity, capital and profits interests.
"Agreement" means this Agreement and the Exhibits and Schedules
attached hereto (or subsequently incorporated herein through amendments hereto),
as the same may be otherwise amended from time to time.
"Authorized Representative" means an Authorized Representative of
each party identified on Schedule "8" hereto.
"Building" means the improvements to be constructed on the Phase II
Land and within the Leasehold Airspace, including the Phase II Hotel/Casino and
the Phase II Mall.
"Build-Out" means Tenant Build-Out and Landlord Build-Out.
"Build-Out Work" means the work of Developer or Tenants, as
applicable, necessary to accomplish the Build-Out.
"Business Day" means any day other than Saturday or Sunday or a
federal holiday and/or the day upon which it is observed.
"Buyer Delay" means any act or omission of Mall II Buyer, any
tenant, or their respective employees, agents, contractors or subcontractors in
connection with the Build-Out Work on the Phase II Land or otherwise, and/or any
delay constituting a Buyer Delay under this Agreement.
"Closing" means the closing of the assignment of the Membership
Interests to Mall II Buyer and the other transactions occurring
contemporaneously therewith as contemplated under this Agreement.
"Closing Instruments" means all instruments, agreements, and
documents required to be executed and/or delivered by Developer, Mall II LLC or
Mall II Buyer, respectively, at the Closing under this Agreement.
"Common Elements" means the common areas and facilities of the
Palazzo Casino Resort as to which any, all, or some Unit Owners will have
access, interest, and/or rights of use pursuant to the Amended REA. The Common
Elements include the "Common Areas" and the "Back-of-House Area" described in
the Initial Plans.
"Competitor" shall mean a Person that (i) owns or operates (or is an
Affiliate of an entity that owns or operates) a hotel located in Xxxxx County,
Nevada or
4
Macau, a convention center located in Xxxxx County, Nevada or Macau or any
casino and/or (ii) is a union pension fund.
"Construction Delay" shall mean any delay caused by an act or
omission of either party, any tenant, or their respective employees, agents,
contractors or subcontractors in connection with the design and construction of
the Mall Improvements that is deemed a Construction Delay under this Agreement.
"Consultant" means an architect, engineer, or other consultant,
and/or any of their respective subconsultants, engaged by a Person with respect
to the design and construction of the Mall Improvements and/or the Build-Out, or
any other portion of the Phase II Land or the Building, as applicable.
"Control" shall have the meaning ascribed to it in the definition of
"Affiliate."
"Developer Delay" means any act or omission of the Developer or its
employees, agents, contractors or subcontractors in connection with construction
of the Mall II Improvements on the Phase II Land and/or any other delay
constituting a Developer Delay under this Agreement.
"Developer's Architect" means HKS Inc. of Nevada (or any successor
designated by Developer).
"Development" means the portion of the Building (including the Mall
Improvements, the Phase II Hotel/Casino and the Build-Out) proposed to be
constructed by Developer on the Phase II Land and Leasehold Airspace.
"Encumbrance" means a Mortgage, security agreement, security
interest, lien, levy, lease, pledge, hypothecation, charge, claim, license,
judgment, covenant, easement, and/or any other encumbrance or restriction of any
and every kind whatsoever.
"Exclusive Mall Equipment" means those portions of the Mall
Equipment that will be used exclusively by or for the benefit of Mall II LLC and
the Phase II Mall and which shall be of a First-Class standard of a similar
quality to that equipment installed in the Phase I Mall.
"Fee Mall Space" means that portion of the Phase II Mall built on
the Phase II Land, including the Casino Shops, to be assigned from Developer to
Mall II LLC.
"Fees and Costs" means reasonable fees of attorneys, architects,
engineers, expert witnesses, consultants, and other Persons, and costs charged
by, or reimbursable to, the foregoing.
"First-Class" means, as of any point in time, in compliance with the
highest standards or of the highest quality, or both, as applicable, in
accordance with
5
then-recognized standards in the industry in question; provided, however, that
wherever the foregoing shall be used in connection with the Phase II Mall, its
meaning shall be with reference to the highest standards or of the highest
quality, or both, as applicable, prevailing as of the date hereof on Las Vegas
Boulevard, Xxxxx County, Nevada, and that wherever the foregoing shall be used
in connection with the Phase II Hotel/Casino, its meaning shall be with
reference to a standard no less than that of the Phase I Hotel/Casino as of the
date hereof.
"Floor Area" means the area in square feet of a designated space
measured from the interior faces of the exterior walls. Calculation of Floor
Area includes those spaces occupied by columns, but excludes the spaces occupied
by stairwells, elevators and mechanical shafts.
"Force Majeure" means any failure of or delay in the availability of
any public utility; any strikes, labor disputes, or unusual delays or shortages
encountered in transportation, fuel, material or labor supplies; casualties;
acts of God or the public enemy; governmental embargo restrictions, or actions
or inactions of any Government Authority (including any delays in issuing
approvals, building permits, certificates of occupancy or other similar permits
or certificates); injunctions; delays caused by the other party; or other acts
or occurrences beyond the reasonable control of a party (provided that any of
the foregoing events or occurrences shall not be Force Majeure if caused by the
party claiming Force Majeure).
"Gaming Authorities" means the Nevada Gaming Commission, the Nevada
State Gaming Control Board, the Xxxxx County Liquor and Gaming Licensing Board
and any other agency or subdivision of the State of Nevada, or any other agency
or subdivision thereof, or of any other Government Authority regulating gaming.
"Gaming Licenses" means every license, franchise or other
authorization to own, lease, operate or otherwise operate gaming activities at
the Venetian Casino Resort or the Palazzo Casino Resort, including all such
licenses granted under the Nevada Gaming Control Act, as codified in Chapter 463
of the Nevada Revised Statutes, as amended from time to time, and the
regulations of the Nevada State Gaming Commission promulgated thereunder, as
amended from time to time, and other applicable federal, state, local or foreign
rules.
"Government Authority" means the United States; the State; Xxxxx
County; any other municipal government authority; any other political
subdivision of any of the foregoing; and any agency, authority, department,
court, commission or other legal entity of any of the foregoing.
"H/C I Owner" means the Venetian Casino Resort, LLC.
"H/C II Space" means, collectively, (x) the Phase II Land and any
buildings and other improvements located thereon, less and except the Phase IA
Airspace, the Phase IA Conference Center and any improvements located within the
6
Phase IA Airspace and (y) the Leasehold Airspace and any buildings and other
improvements located therein.
"Hazardous Material(s)" means materials, substances, fluids,
chemicals, gases, or other compounds the presence, use, storage, emission,
drainage, leakage, effusion, modification, or disposition of which is prohibited
by law or is subject by law to specific procedures, controls, or restrictions,
or which are otherwise deemed toxic, poisonous, or unsafe. However, "Hazardous
Materials" shall not include substances which are used in compliance with
applicable laws in the ordinary course of a business use. "Hazardous Materials"
include, in any event, asbestos, lead paint, and PCBs.
"Impositions" means all real estate and personal property taxes,
general and special assessments, water and sewer charges, road maintenance and
other infrastructure charges, license fees and other fees and charges assessed
or imposed by Government Authorities or quasi-Government Authorities upon the
Phase II Mall.
"Institutional Investor" means a savings bank, savings and loan
association, a commercial bank or trust company (whether acting individually, or
in any fiduciary capacity), an insurance company, an educational institution, a
corporate employees', or state, municipal or similar public employees' welfare
or other pension or retirement fund or system, an investment bank, a mutual fund
or a commercial finance company.
"Interest Rate" means the rate at which Mall II Buyer can borrow
funds under the corporate credit line of General Growth Properties, Inc. as of
the Closing Date, Earn-Out Date, an Interim Payment Date or the Final Date, as
applicable.
"Landlord Build-Out" means the installations, furnishing, finishes,
fixtures, equipment, fitting-out and other tenant improvement work to be
constructed by the landlord under any Lease in order to prepare the Tenant
Spaces for occupancy by Tenants, provided that, in all events, Landlord
Build-Out does not include any Tenant Build-Out.
"Landlord Build-Out Work" means the work of Developer necessary to
accomplish the Landlord Build-Out.
"Lease" means any lease, license, occupancy agreement or other
agreement (including any use or occupancy arrangements created pursuant to
Section 365 of the Bankruptcy Code or otherwise in connection with any
bankruptcy or insolvency proceeding in respect of any tenant or occupant)
demising or otherwise permitting the possession, occupancy, use or enjoyment of
the Phase II Mall or any part thereof (including, without limitation, any
concession or kiosk space), and every modification, supplement or extension
thereof.
"Leasehold Mall Space" means that portion of the Phase II Mall to be
built in the Leasehold Airspace.
7
"Leasing Costs" shall mean, with respect to all Leases in the
aggregate, the sum of all leasing commissions payable by Mall II LLC, or
Developer on behalf of Mall II LLC, to third party brokers, the cost of all
tenant improvement allowances payable by or tenant improvement work to be
performed by Mall II LLC, or Developer on behalf of Mall II LLC, in connection
with the commencement of a Lease and as required under such Lease, legal fees
payable by Mall II LLC, or Developer on behalf of Mall II LLC, to outside
attorneys or to Mall II Buyer's in-house counsel at the rates set forth on
Schedule "13" attached hereto and made a part hereof, and all other amounts paid
or payable by Mall II LLC, or Developer on behalf of Mall II LLC, to a Tenant or
third party in connection with the commencement of a Lease.
"Legal Proceeding" means an action, litigation, arbitration,
administrative proceeding, and other legal or equitable proceeding of any kind.
"Legal Requirements" mean all statutes, laws, ordinances, rules,
regulations, executive orders and requirements of all Government Authorities
which are applicable to the Phase II Mall or any part thereof or the use or
manner of use thereof, or to owners or occupants thereof in connection with such
ownership, occupancy or use.
"Mall Equipment" means machinery, equipment, fixtures, and other
tangible personal property which do not constitute real property and which will
be installed in, affixed to, and/or constructed as part of, the Mall
Improvements.
"Mall I Buyer" means the "Purchaser" under and as defined in the
Phase I Mall Sale Agreement.
"Mall I LLC" means Grand Canal Shops II, LLC.
"Mall II Unit" means the Phase II Mall excluding the Common Elements
contained therein.
"Mall Improvements" means certain improvements relating to the Phase
II Mall portion of the Palazzo Casino Resort (and also certain Common Elements
and/or other items) to be designed and constructed by Developer, as described in
Articles 2 and 3 of this Agreement and the Initial Plans, as the same may be
modified pursuant to the terms of this Agreement.
"Mortgage" means a mortgage or deed of trust.
"Permitted Encumbrances" means the Encumbrances described in
Schedule "5."
"Person" means an individual person, a corporation, partnership,
trust, joint venture, limited liability company, proprietorship, estate,
association, land trust, other trust, Government Authority or other incorporated
or unincorporated enterprise, entity or organization of any kind.
8
"Phase I Hotel/Casino" means the hotel/casino to be operated in the
Venetian Casino Resort.
"Phase I Mall" shall have the meaning ascribed to it in the REA.
"Phase I Mall Sale Agreement" means that certain Purchase and Sale
Agreement dated as of even date herewith by and among Grand Canal Shops Mall MM
Subsidiary, Inc., Grand Canal Shops Mall Subsidiary, LLC and Mall I Buyer.
"Phase IA Airspace" means a portion of the airspace above the Phase
II Land, as more particularly described in Schedule "3" attached hereto and made
a part hereof.
"Phase IA Conference Center" means the approximately 150,000 square
feet of additional meeting and conference space located in the Phase IA
Airspace.
"Phase II Automobile Parking Area" means a new and separate parking
structure that Developer intends to construct on the Phase II Land for the use
by, among others, Developer and Mall II LLC.
"Phase II Hotel/Casino" means the hotel/casino constructed and
operated by Developer in the H/C II Space.
"Phase II Mall Documents" means the following: (a) all drawings,
plans, contracts, licenses, warranties and specifications for the Mall
Improvements to be delivered to Mall II LLC at the Closing, and all operating
manuals for the Exclusive Mall Equipment; and (b) Developer's books, records,
and correspondence pertaining to the Service Contracts assumed by Mall II LLC or
to which Mall II LLC will remain a party (if any) and the operation, maintenance
and repair of the Exclusive Mall Equipment.
"Required Mall Improvement Permits" means all permits and approvals
of and from applicable Government Authorities which are necessary for the
construction and completion of the Mall Improvements and the delivery of same to
Mall II Buyer (specifically excluding, without limitation, temporary or
permanent certificates of occupancy for individual Tenant Spaces).
"Service Contract" means any contract or agreement to which
Developer or Mall II LLC is a party for the furnishing of management,
maintenance, repairs, supplies, or other services exclusively to the Phase II
Mall, and all amendments thereof, which will have a term expiring after the
Closing Date (and which cannot be cancelled without penalty on not more than 30
days' prior notice).
"State" means the State of Nevada.
"Tenant" means the tenant, licensee, occupant or other user to which
rights are granted under a Lease.
9
"Tenant Build-Out" means the installations, furnishing, finishes,
fixtures, equipment, fitting-out and other tenant improvement work to be
constructed by any Tenant as required or permitted under the Leases in order to
prepare the Tenant Spaces for occupancy by Tenants.
"Tenant Build-Out Work" means the work of Tenants necessary to
accomplish the Tenant Build-Out.
"Tenant Space" means the portions of the Phase II Mall to be demised
to and occupied by individual Tenants.
"Title Insurance Commitment" means a commitment to issue an owner's
policy of title insurance insuring the fee simple title in the Fee Mall Space
and leasehold title to the Leasehold Mall Space and the Casino Shops in Title
Insurer's standard form.
"Title Insurer(s)" means any title insurance company or companies
selected by Mall II Buyer to issue the Title Insurance Commitment.
"Unit Owner" means any entity which is a party to the REA or the
Amended REA and such party's respective successors and assigns.
"Use and Occupancy" means use and occupancy as described in this
Agreement of the Phase II Mall by Mall II LLC for Mall II Buyer's intended
purposes.
1.2 Wherever used in this Agreement:
(a) the words "include" or "including" shall be construed as
incorporating, also, "but not limited to" or "without limitation;"
(b) the word "day" means a calendar day unless otherwise
specified;
(c) the phrase "at Developer's expense" shall mean at the sole
cost and expense of Developer, but the payments to be made to Developer pursuant
to Article 20 herein shall be unaffected by the use of such phrase;
(d) the phrase "at Mall II Buyer's expense," shall mean at the
sole cost and expense of Mall II Buyer;
(e) the word "party" means each signatory to this Agreement;
(f) the word "law" (or "laws") means any law, rule,
regulation, order, statute, ordinance, resolution, regulation, code, decree,
judgment, injunction, mandate or other legally binding requirement of a
Government Authority applicable in the particular context;
(g) the word "notice" shall mean notice in writing (whether or
not specifically so stated);
10
(h) "month" means a calendar month unless otherwise specified;
(i) the word "amended" means "amended, modified, extended,
renewed, changed, or otherwise revised"; and the word "amendment" means
"amendment, modification, extension, change, renewal, or other revision;"
(j) the phrase "subject to the terms of this Agreement" means
"upon and subject to all terms, covenants, conditions and provisions of this
Agreement;"
(k) the word "delay" means a delay or interference to a
particular schedule which (i) will require more than a minimal rearrangement of
(or delay in) other activities or commitments by the affected party; (ii) was
not caused by action or inaction of the affected party; and (iii) is the sole
cause of the rearrangement of (or delay in) other activities or commitments by
the affected party;
(l) the word "recorded" means submitted to the Recorder's
Office of Xxxxx County, Nevada; and
(m) the words "utility" (or "utilities") means gas, water,
chilled water, sewer, electricity, steam, power, and other utilities of any
kind.
1.3 For purposes of this Agreement and except as set forth in
Section 15.10, a party shall be deemed to have knowledge or notice of a matter
if such matter is actually known by, or if written notice disclosing such matter
has been given to an officer, director or individual general partner, member,
manager, or shareholder of such party or of a Person controlling such party.
1.4 Other words and phrases are defined elsewhere in this Agreement
and listed in the Index of Defined Terms.
ARTICLE 2
DESIGN OF MALL IMPROVEMENTS
2.1 Initial Plans and Creation of Construction Drawings.
(a) The Standards Document. Exhibit "A" attached hereto and
made a part hereof is that certain Palazzo Casino Resort, Retail Standards
Document which contains a description of certain details of the development and
construction of the Mall Improvements (the "Standards Document"). The Character
Sketches attached to the Standards Document are intended to illustrate the look
and feel of the Xxxxxxx Hills/Rodeo Drive theme only and shall not be binding as
to the particulars of the design or layout shown. Developer shall have the right
to change the Xxxxxxx Hills/Rodeo Drive theme upon prior notice to and written
consent by Mall II Buyer, which consent shall not be unreasonably withheld or
delayed.
11
(b) Common Area Plans. Promptly upon execution of this
Agreement, Developer and Mall II Buyer shall negotiate expeditiously and in good
faith to develop a plan that is consistent with the Standards Document for the
location of the public common areas that will become part of the Common Elements
(the "Common Area Plans" and, together with the Standards Document, as the same
may be revised pursuant to this Agreement, the "Initial Plans"). Developer and
Mall II Buyer shall agree upon a Common Area Plan no later than ninety (90) days
following the date of execution of this Agreement. In the event that Developer
and Mall II Buyer, despite good faith efforts, have not agreed upon a Common
Area Plan as of such date, then the same shall constitute a Construction Delay
(the duration of which shall be one (1) day for each day after said ninety (90)
day period that the parties shall have failed to agree on a Common Area Plan).
(c) Construction Drawings and Specs.
(i) Development of Construction Drawings and Specs.
Developer will proceed, in consultation with Mall II Buyer, with the development
of construction drawings and specifications for the Mall Improvements. To this
end, Developer shall give to Mall II Buyer, for review, the construction
drawings and specifications at 50%, 75% and 100% of completion (each of the
foregoing, the "Initial Construction Drawings and Specs"). Within ten (10)
Business Days after the receipt by Mall II Buyer of each of the Initial
Construction Drawings and Specs, time being of the essence, Mall II Buyer will
have the right to submit comments to Developer and to object to any feature
shown in the Initial Construction Drawings and Specs that deviates from the
Initial Plans. Developer and Mall II Buyer will consult to resolve any issues,
but Developer may proceed with the development of the construction drawings and
specifications notwithstanding Mall II Buyer's objection, subject to Mall II
Buyer's rights under this Section 2.1(c) and Article 10. To the extent that any
feature is not in conformance with the Initial Plans, Developer shall correct
such feature in the Initial Construction Drawings and Specs at Developer's
Expense. If any feature shown in any Initial Construction Drawings and Specs is
in accordance with the Initial Plans and Mall II Buyer requests a change to such
feature, such request shall be considered a request for a change to the Initial
Plans and shall be subject to Developer's approval pursuant to Section 3.3(b) of
this Agreement. Developer will furnish interpretations, explanations and
additional information if and as requested by Mall II Buyer within the ten (10)
Business Day period provided for in this Section, but the same shall not have
the effect of extending said ten-Business Day period.
(ii) Mall II Buyer Approval of Construction Drawings and
Specs. Within ten (10) Business Days after the receipt by Mall II Buyer of the
final version of the Initial Construction Drawings and Specs (i.e., at 100%
completion), time being of the essence, Mall II Buyer shall approve such Initial
Construction Drawings and Specs or submit specific objections to any feature
shown in such final Initial Construction Drawings and Specs that deviates from
the Initial Plans. Developer and Mall II Buyer will consult, in good faith, to
resolve such objections. In the event such Initial Construction Drawings and
Specs shall deviate from the Initial Plans, Developer shall revise such Initial
Construction Drawings and Specs one or more times and resubmit the
12
same to Mall II Buyer for approval, which shall be given or denied, in each
case, within ten (10) Business Days, time being of the essence. At such time as
Mall II Buyer approves such Initial Construction Drawings and Specs as in
accordance with the Initial Plans (or waives any deviation), Mall II Buyer shall
deliver a written notice to Developer approving such Initial Construction
Drawings and Specs (as so approved and as the same may be modified pursuant to
the terms of this Agreement, the "Final Construction Drawings and Specs"). If
Mall II Buyer shall withhold or delay (beyond the then-applicable ten (10)
Business Day period) its approval of any Initial Construction Drawings and Specs
for any reason, unless the same shall deviate from the Initial Plans, then the
same shall constitute a Construction Delay (the duration of which shall be one
(1) day for each day after said ten (10) Business Day period that the Final
Construction Drawings and Specs are not approved) for the purposes of this
Agreement. If any feature shown in any Final Construction Drawings and Specs is
in accordance with the Initial Plans and Mall II Buyer requests a change to such
feature, such request shall be considered a request for a change to the Initial
Plans and shall be subject to Developer's approval pursuant to Section 3.3(b) of
this Agreement. In the event Developer desires to amend the Final Construction
Drawings and Specs in any material respect, such amendment shall be subject to
Mall II Buyer's review and approval in accordance with this subsection
2.1(c)(ii), except that Mall II Buyer shall have five (5) Business Days to
respond to any request for amendment.
2.2 Elements of Design of the Mall Improvements; Demising Walls.
(a) Elements of the Standards Document. The Standards Document
identifies the components of the Mall Improvements and set forth certain
locational, dimensional and design requirements pertaining to the Phase II Mall.
In particular, the Standards Document contains descriptions of (i) the
back-of-house area (for circulation of mall tenants and employees), (ii) the
publicly accessible Common Elements that will serve as access to the retail
spaces and the Phase II Hotel/Casino and (iii) the standards for construction of
certain elements of retail and restaurant Tenant Spaces.
(b) Required Elements of the Phase II Hotel/Casino. The
drawings and written specifications and requirements in the Initial Plans do not
include details for the Phase II Hotel/Casino or certain of the Common Elements
located outside the Phase II Mall. The Developer shall be obligated to design
and construct a First-Class hotel and casino with no less than 2,000 guest rooms
on the Phase II Land and in the Leasehold Airspace; provided, that the
completion of such hotel and casino shall not be a condition precedent to
Closing, except as expressly provided in this Agreement.
(c) Demising Walls. The Initial Plans do not set forth the
location of demising walls between the Tenant Spaces or between the Tenant
Spaces and the Common Elements of the Phase II Mall (the "Demising Walls"),
which have not yet been finally determined. The location of the Demising Walls
shall be determined jointly by Mall II Buyer and Developer as the parties
identify Tenants for the retail and restaurant Tenant Spaces in two stages,
described as follows:
13
(i) Upon final determination of the Common Area Plans by
the parties, Mall II Buyer and Developer shall negotiate expeditiously and in
good faith to develop a plan for the location of the Demising Walls that is
consistent with the Initial Plans and/or the Final Construction Drawings and
Specs, if the same have been agreed upon, identifying whether each Tenant Space
will be occupied by a restaurant or retail tenant, showing the specifications
and points of connection with the Tenant Space of all utilities required for
each such Tenant Space and identifying the location of smoke walls (as the same
may be modified in accordance with this Agreement, the "Initial Demising Wall
Plan"). Mall II Buyer and Developer shall agree upon an Initial Demising Wall
Plan no later than six (6) months after the date of execution of this Agreement.
In the event that Mall II Buyer and Developer, despite good faith efforts, have
not agreed upon an Initial Demising Wall Plan by such date, the same shall
constitute a Construction Delay (the duration of which shall be one (1) day for
each day after said six (6) month period that the parties shall have failed to
agree on an Initial Demising Wall Plan).
(ii) Upon the final determination of the Initial
Demising Wall Plan, Mall II Buyer and Developer shall negotiate expeditiously
and in good faith to supplement the same to show the location, consistent with
the Initial Plans, of all Demising Walls (as the same may be modified in
accordance with this Agreement, the "Final Demising Wall Plan"). Mall II Buyer
and Developer shall agree upon a Final Demising Wall Plan no later than one (1)
year after the date of execution of this Agreement. In the event that Mall II
Buyer and Developer, despite good faith efforts, have not agreed upon a Final
Demising Wall Plan by such date, the same shall constitute a Construction Delay
(the duration of which shall be one (1) day for each day after said one (1) year
period that the parties have failed to agree on a Final Demising Wall Plan).
2.3 Calculation of Floor Area.
(a) The Phase II Mall is intended to consist of 118,000 square
feet of Floor Area of Leasehold Mall Space (the "Projected Leasehold Floor
Area") and 279,018 square feet of Floor Area of Fee Mall Space (the "Projected
Fee Floor Area"). Mall II Buyer and Developer acknowledge and agree that the
actual as-built Floor Area of the Leasehold Mall Space and the Fee Mall Space
may be greater or less than the Projected Leasehold Floor Area and the Projected
Fee Floor Area, respectively. Developer may, subject to the following provisions
of this Section 2.3, deliver to Mall II LLC an actual as-built Floor Area of the
Leasehold Mall Space and/or the Fee Mall Space that varies from the Projected
Leasehold Floor Area and the Projected Fee Floor Area, provided that (x) (unless
reductions in Floor Area are necessary in order to comply with Legal
Requirements, to obtain Required Mall Improvement Permits or to make design
changes that are reasonably necessary to insure the efficient operation of the
Building, in which event the Required Leasehold Floor Area and the Required Fee
Floor Area shall be further reduced as so required) (i) the Floor Area of the
Leasehold Mall Space shall not be less than 95% of the Projected Leasehold Floor
Area (the "Required Leasehold Floor Area") and (ii) the Floor Area of the Fee
Mall Space shall not be less 95% of the Projected Fee Floor Area (the "Required
Fee Floor Area") and (y) in no event shall (i) the as-built Floor Area of the
Leasehold Mall Space be greater than 105% of the
14
Projected Leasehold Floor Area or (ii) the as-built Floor Area of the Fee Mall
Space be greater than 105% of the Projected Fee Floor Area, without the prior
consent of Mall II Buyer, not to be unreasonably withheld or delayed.
(b) As promptly as possible after Developer delivers to Mall
II Buyer the notice of the Anticipated Completion Date, Developer and Mall II
Buyer shall attempt to agree on the as-built square footage of the Floor Area
included in the Mall Improvements for each of the Leasehold Mall Space and the
Fee Mall Space (the "As-Built Floor Area"). If Developer and Mall II Buyer are
unable to agree on which portions of the Mall Improvements are As-Built Floor
Area or any calculation of As-Built Floor Area, Developer and Mall II Buyer
shall engage an Independent Expert to resolve such disputes pursuant to the
provisions of Article 9.
2.4 Consultants. Developer and Mall II Buyer each shall engage its
own Consultants with respect to the design and construction of the Development
and the Build-Out. Developer's and Mall II Buyer's Consultants shall consult
with each other for purposes of coordinating filings with the relevant
Government Authorities and related matters. Developer shall endeavor to deliver
all contracts with the general contractor, if other than Developer, and primary
subcontractors to Mall II Buyer no later than five (5) Business Days prior to
execution of such contracts. The delivery of such contracts to Mall II Buyer
shall be for informational purposes only and Mall II Buyer's consent shall not
be required to any contracts.
ARTICLE 3
CONSTRUCTION OF MALL IMPROVEMENTS
3.1 Construction by Developer.
(a) At Developer's expense, Developer shall construct the Mall
Improvements substantially in accordance with the Final Construction Drawings
and Specs and this Agreement, subject to Section 3.3 of this Agreement.
Developer shall construct the improvements to the standard of a First-Class Mall
of a level of quality substantially similar to that of the "Grand Canal Shoppes
at the Venetian" as of the date hereof. Developer shall diligently pursue all
Required Mall Improvement Permits. Developer shall cause the Mall Improvements
to be constructed free from material fault or defect; of good quality; in a
xxxxxxx-like manner and incorporating only new materials and equipment; by means
and methods complying with applicable Legal Requirements and insurance
requirements; and so as to operate properly and otherwise in accordance with the
requirements of the Final Construction Drawings and Specs.
(b) At Developer's expense, Developer shall complete, repair,
replace, rebuild and/or correct promptly all Mall Improvement work which is
incorrect, defective, incomplete, omitted, or not otherwise in compliance with
the Final Construction Drawings and Specs, as the same may have been modified
pursuant to the provisions of Section 3.3 of this Agreement, which Developer
discovers, or of which
15
Mall II Buyer or Mall II LLC gives written notice to Developer, prior to
Substantial Completion.
3.2 Inspection by Mall II Buyer. Mall II Buyer shall have the right
during usual business hours, at Mall II Buyer's expense and upon reasonable
notice to Developer, (a) to inspect the construction work of the Mall
Improvements to ascertain that the performance of such work adheres to the Final
Construction Drawings and Specs, and (b) without limiting the foregoing, to
review shop drawings for the Mall Improvement work. In any event, during the
last week of each month (or on such other regularly-established monthly date as
Developer shall designate as the regular inspection date), Mall II Buyer and/or
its Consultants shall inspect the Mall Improvements construction work performed
since the prior inspection. Based on such observation, Mall II Buyer shall
furnish to Developer a statement, in a form to be agreed by the parties,
relating to Mall II Buyer's objections with respect to the construction work
(the "Mall II Buyer Monthly Statement"). However, issuance of the Mall II Buyer
Monthly Statement will not be construed as Mall II Buyer's acceptance of work
which is defective, incomplete, or otherwise not in compliance with the Final
Construction Drawings and Specs, or as Mall II Buyer's waiver of any rights
under this Agreement, or as Mall II Buyer's release of Developer or any of
Developer's contractors or any surety from any warranty, guarantee, or
obligation provided under this Agreement or the Final Construction Drawings and
Specs or the applicable construction contract(s).
3.3 Construction Changes.
(a) Changes to the Mall Improvements (whether before or after
commencement of construction) made by Developer that are consistent with the
Final Construction Drawings and Specs (or the Initial Plans, if the Final
Construction Drawings and Specs have not been agreed to pursuant to the terms of
this Agreement) and the Initial Demising Wall Plan or Final Demising Wall Plan,
after the same have been agreed to, may be made without Mall II Buyer's
approval, subject to Section 2.3. Changes to the Mall Improvements requested by
Developer that are not consistent with the Final Construction Drawings and Specs
(or the Initial Plans, if the Final Construction Drawings and Specs have not
been agreed to pursuant to the terms of this Agreement) and changes to the
Initial Demising Wall Plan, the Final Demising Wall Plan or the Common Area
Plan, after the same have been agreed to by Developer and Mall II Buyer, shall
be subject to Mall II Buyer's approval, which shall not be unreasonably withheld
or delayed if such change will not result in a failure of Developer to deliver
the Required Leasehold Floor Area or the Required Fee Floor Area.
(b) Changes in the Final Construction Drawings and Specs (or
the Standards Document, if the Final Construction Drawings and Specs have not
been agreed to pursuant to the terms of this Agreement), the Mall Improvements,
the Initial Demising Wall Plan, the Final Demising Wall Plan and the Common Area
Plan, after the same have been agreed to by Developer and Mall II Buyer, that
are requested by Mall II Buyer shall be subject to Developer's approval, which
shall not be unreasonably withheld or delayed if such change (i) will not
require more than de minimis changes to the Building other than the Mall II
Unit, (ii) will not cause, in Developer's reasonable
16
judgment, a material delay in the completion of the Development, (iii) will not
adversely effect the Phase II Hotel/Casino and (iv) will not increase by more
than a de minimis amount the cost of constructing the Building and/or the Mall
II Unit unless Mall II Buyer agrees to pay such cost increase as and when
incurred.
(c) If a change in the Initial Plans, the Final Construction
Drawings and Specs, the Initial Demising Wall Plan, the Final Demising Wall
Plan, after the same have been agreed to, or the Mall Improvements is required
by law or in order to obtain any Required Mall Improvement Permits, Developer
shall advise and promptly consult with Mall II Buyer as to the particular
requirements and the solution or solutions it is considering. If such change is
required by any Governmental Authority in order to issue a Required Mall
Improvement Permit, or if such change is consistent with the Standards Document,
Developer shall not be required to obtain Mall II Buyer's prior written approval
for the proposed manner of compliance; provided that, to the extent economically
feasible, Developer will make such change in the way that has the least impact
on the Initial Plans, the Final Construction Drawings and Specs, the Initial
Demising Wall Plan, the Final Demising Wall Plan and the Mall Improvements and
the Final Construction Drawings and Specs shall be modified accordingly. With
respect to any other such change, Developer and Mall II Buyer shall reasonably
agree on necessary and appropriate changes to be made to the Initial Plans, the
Final Construction Drawings and Specs, the Initial Demising Wall Plan, the Final
Demising Wall Plan and/or the Mall Improvements in order to comply with the
Legal Requirements or obtain the necessary permits, as applicable. In the event
that Developer proposes a method of compliance and Mall II Buyer requests that
Developer choose another method of compliance, Mall II Buyer shall pay to
Developer or reimburse Developer at Closing for any incremental costs (over the
cost of the method chosen by Developer) to effect such other method of
compliance. Developer shall pay any change costs associated with changes in the
Mall Improvements due to requirements of laws or inability to obtain necessary
permits, except as provided in the immediately preceding sentence, but shall not
pay associated fees of Mall II Buyer's Consultants (unless the legal compliance
requirement was a result of negligent acts or omissions of Developer or its
Consultants, as reasonably determined by the Independent Expert).
(d) In this Agreement, "Field Changes" means minor and routine
changes necessitated by conditions in the field which are customarily resolved
by architects and construction managers and have no material cost or design
ramifications. Field Changes in the Mall Improvements and the Build-Out shall be
subject to approval by Developer's site representative (who shall act promptly)
in cooperation with Mall II Buyer's Site Representative (who shall act
promptly).
3.4 Construction Warranties.
(a) This Section governs construction warranties or guaranties
covering or otherwise applicable to those portions of the Mall Improvements
which will be part of the Common Elements ("CE Warranty Work") and those
portions of the Mall Improvements which will not be part of the Common Elements
but will be the
17
responsibility of Mall II LLC and/or Mall II Buyer to maintain in accordance
with the Amended REA (collectively, "Mall II Unit Warranty Work").
(b) As to both CE Warranty Work and Mall II Unit Warranty
Work, Developer shall include in its contracts with construction contractors
warranty/guaranty provisions customary for the type or category of work involved
(any such provision, a "Contractor Warranty") under which the respective
contractor will be required, at its expense, to repair, replace, and/or correct
work which is incorrect, defective, incomplete, or not otherwise in compliance
with the Final Construction Drawings and Specs ("Defective Work"). Developer
shall use commercially reasonable efforts to obtain the agreement of the
respective contractor (i) that Mall II LLC and Mall II Buyer shall be the
beneficiaries of, and may enforce directly, the contractor's Contractor Warranty
as to any Mall II Unit Warranty Work and/or CE Warranty Work located in the
Phase II Mall and (ii) that Mall II LLC and/or Mall II Buyer (and/or other Unit
Owners) may enforce their applicable warranties without set-off or defense by
reason of disputes between the Contractor and Developer (a "No-Offset Clause").
Any such Contractor Warranty for CE Warranty Work may also provide that other
Unit Owners are third party beneficiaries.
(c) As to both CE Warranty Work and Mall II Unit Warranty
Work, until Developer has closed out the applicable contract and made final
payment (including release of retainage) to a contractor ("Close-Out"),
Developer shall use best efforts, at Developer's expense, to enforce the
applicable Contractor Warranty in accordance with its terms and conditions so as
to cause such contractor, at such contractor's expense, to repair, replace,
and/or correct Defective Work of which Developer becomes aware or of which
either Mall II LLC and/or Mall II Buyer gives notice to Developer. If there is
any dispute regarding whether any work performed is Defective Work, Developer
and Mall II Buyer shall submit the dispute for resolution to the Independent
Expert, and the determination of the Independent Expert shall be binding.
(d) After Close-Out of a contract with a Contractor Warranty
for CE Warranty Work, Developer shall assign Developer's rights with respect to
such Contractor Warranty to the party responsible for maintaining such Common
Element, if not Developer.
(e) After Close-Out of a contract with a Contractor Warranty
for Mall II Unit Warranty Work, Developer shall assign (on a non-exclusive
basis) Developer's rights with respect to such Contractor Warranty to Mall II
LLC. If Developer obtains and delivers to Mall II LLC a No-Offset Clause from a
particular contractor, Mall II LLC may thereafter enforce the Contractor
Warranty against such contractor, and Developer will have no further obligations
to do so. However, if Developer is unable to obtain a No-Offset Clause from a
particular contractor and the contractor raises on-going claims with Developer
as a defense in any claim by Mall II LLC for Defective Work against such
contractor, then Developer shall use Developer's best efforts, at Developer's
expense, to enforce the applicable Contractor Warranty in accordance with its
terms and conditions so as to cause such contractor, at such
18
contractor's expense, to repair, replace, and/or correct such Defective Work.
Moreover, if Developer has failed to obtain any Contractor Warranty that Mall II
LLC can enforce for the work of a particular contractor relating to any
particular Mall II Unit Warranty Work, Developer shall be responsible, at
Developer's expense, to repair, replace, and/or correct Defective Work in the
work of such contractor for a period of time equal to the length of a typical
warranty period for such work or one year from the date the item or work is
placed in service if there is no typical warranty period.
(f) Developer will permit Mall II Buyer and its Consultants to
review, and will consult with them concerning, the text, terms, and conditions
of proposed Contractor Warranties for contractors who will perform the Mall
Improvement work which could become either CE Warranty Work or Mall II Unit
Warranty Work.
(g) In the event that Developer does not engage a general
contractor to construct the Mall Improvements, at Closing, Developer shall
deliver to Mall II Buyer a warranty covering the construction of the Mall
Improvements on terms consistent with those typically offered by general
contractors with respect to similar projects (the "Developer's Warranty"). In
such event, the covenants with respect to construction contracts and warranties
thereunder set forth in Section 3.4(b), the first sentence of Section 3.4(c) and
Sections 3.4(d) and 3.4(e) shall be inapplicable and Developer shall retain the
right to enforce all Contractor Warranties.
(h) The provisions of this Section 3.4 shall survive the
Closing.
3.5 Developer's Indemnification.
(a) Developer agrees (at Developer's expense) to indemnify,
defend and hold harmless Mall II LLC, Mall II Buyer and their respective
directors, officers, stockholders, partners, members and employees (the
foregoing collectively the "Mall Indemnitees") from and against any loss,
liability, damage, cost, or expense (including Fees and Costs) which any of them
may suffer, or which may be asserted against any of them, in whole or in part by
reason of, or in connection with: (i) any bodily injury, sickness, disease or
death of or to any person or persons, or any damage to or destruction of
property, arising out of or resulting from acts or omissions of Developer, Mall
II LLC (to the extent taken or occurring prior to Closing) or Developer's
contractors or subcontractors in connection with the Mall Improvements or other
construction work relating to the Development, whether on the Phase II Land or
elsewhere; (ii) any failure by Developer, Mall II LLC (to the extent occurring
prior to Closing) or Developer's contractors or subcontractors to comply with
applicable Legal Requirements or insurance requirements; (iii) the use or misuse
by Developer, Mall II LLC (to the extent occurring prior to Closing) or
Developer's contractors or subcontractors of Hazardous Materials on the Phase II
Land; (iv) infringement of patent rights, licensing or royalty agreements, or
trade secrets by Developer, Mall II LLC (to the extent occurring prior to
Closing) or Developer's contractors or subcontractors in connection with the
Mall Improvements or other construction work relating to the Development,
whether on the Phase II Land or elsewhere; (v) any liens filed against the Phase
II Mall by any Person claiming by, through, or under Developer or Mall II LLC
(to
19
the extent relating to claims accruing before Closing); and/or (vi) any claims
under Developer's Warranty.
(b) Developer shall defend any Legal Proceedings commenced
against any of the Mall Indemnitees concerning any matter covered by the
foregoing indemnification. Developer shall give Mall II Buyer copies of
documents served in any such Legal Proceeding and shall advise Mall II Buyer
regularly as to the status of the same. If Developer fails to defend diligently
against any such Legal Proceeding, or if Mall II Buyer reasonably believes that
Developer's interest in such Legal Proceeding is adverse to Mall II Buyer's
interest therein, Mall II Buyer shall have the right (but not the obligation),
upon ten (10) Business Day's prior written notice, to defend the same at
Developer's expense. Developer shall not settle any such Legal Proceeding
without the written consent of Mall II Buyer (unless such settlement shall
release each Mall Indemnitee against whom liability has been asserted from all
liability with respect to such Legal Proceeding without contribution from such
Indemnitee). No Mall Indemnitee may settle any such Legal Proceeding without the
written consent of Developer, which consent shall not be unreasonably withheld
or delayed.
(c) Mall II Buyer shall notify Developer promptly of every
Legal Proceeding or claim which may be covered by the indemnification in (a)
above. Developer's obligations under this Section 3.5 shall not be limited or
defined by the amount of insurance carried by Developer or by limitations on
amount or type of damages under worker's compensation acts or other laws
relating to employee benefits.
(d) This Section shall not require indemnification of any Mall
II Buyer Indemnitee to the extent of the negligence or willful misconduct of
Mall II Buyer, or of Mall II LLC after the transfer of the Membership Interests
to Mall II Buyer, any of their respective agents or affiliated Persons, or
another Mall Indemnitee.
(e) The provisions of this Section 3.5 shall survive the
Closing.
3.6 Insurance Coverages. At Developer's expense, Developer shall
include Mall II LLC and Mall II Buyer as an additional insured on each policy of
liability insurance carried by Developer with respect to the Development with an
aggregate limit of not less than $25,000,000. Alternatively, the parties may
agree that Mall II LLC, Mall II Buyer and Developer may be included as insureds
under one or more liability policies covering the Mall Improvements and the
entire Development. Developer will carry, at Developer's expense, a policy of
builder's risk insurance for full replacement value (exclusive of footings and
foundations) on a completed value (reporting) basis and upon other commercially
standard terms and conditions covering construction of the Mall Improvements.
3.7 Coordination of Build-Out. All Landlord Build-Out Work will be
performed and coordinated by Developer upon consultation with Mall II Buyer. The
parties recognize that it may be necessary or appropriate for Tenants and their
contractors and subcontractors to have access to the Phase II Mall before the
Closing to supervise and perform Tenant Build-Out Work, including any Tenant
Build-
20
Out Work which should be completed early in the process of constructing the Mall
Improvements (such as, for example, installation of wiring and conduit) to avoid
uncovering of completed Mall Improvement work after commencement of Tenant
Build-Out or otherwise to avoid re-doing of, or disruption to, the Mall
Improvement work. Mall II Buyer understands that the contractors and
subcontractors of any Tenant supervising and performing any Tenant Build-Out
Work will be subject to the direction and coordination of Developer and its
construction manager and Mall II Buyer and/or Developer shall so inform each
Tenant. Developer shall give written notice to Mall II Buyer (a "Build-Out
Notice") when, in Developer's good faith judgment, the Mall Improvements or a
portion thereof have reached a stage of construction where it is safe and
appropriate for Tenants to have access to the Mall I Improvements or such
portion of the Mall Improvements for the purposes of supervising and performing
the Tenant Build-Out Work and such access will not interfere unreasonably with
construction of the Mall Improvements. At the Developer's election and based on
the progress of construction of the Building, the Build-Out Notice may be given
as one notice or a series of notices, each of which may give Tenants and their
respective contractors and subcontractors access to all or a portion of the Mall
II Improvements. After the giving of a Build-Out Notice, Tenant's contractors
shall have the right to enter the portions of the Phase II Mall covered by such
Build-Out Notice upon twenty-four (24) hours prior telephonic notice to
Developer for the purposes of performing the Tenant Build-Out Work. Developer
shall reasonably accommodate the scheduling of Tenant Build-Out Work (if any),
provided that the same will not interfere with the progress of the Mall
Improvement work. After the commencement of the Tenant Build-Out Work, Developer
may, from time to time, restrict Mall II Buyer's, any Tenant's or their
respective contractor's or subcontractor's access to the Mall Improvements in
order to complete other necessary construction work in the Mall Improvements and
on the Phase II Land. Developer shall use good faith efforts to keep such work
disruptions to a minimum and to schedule such disruptions so as to cause minimal
disruption to the completion of the Tenant Build-Out Work. Developer will obtain
at its expense permits with respect to Landlord Build-Out Work that it is
performing and Developer and Mall II Buyer shall jointly cause each Tenant to
obtain, all permits and approvals for construction of the Tenant Build-Out Work
that such Tenant is performing, other than the Required Mall Improvement Permits
(which Developer shall obtain at Developer's Expense). All Landlord Build-Out
Work shall be performed at the sole expense of Developer, and Mall II Buyer
shall not be responsible to pay any amount in regard of the Landlord Build-Out
Work. Entry by any Tenant or its contractors or subcontractors to perform Tenant
Build-Out Work shall not be deemed acceptance of the Mall Improvements by Mall
II Buyer or a waiver of Mall II Buyer's rights under this Agreement. Mall II
Buyer and Developer shall jointly cause Tenants and any contractors and
subcontractors, in performing the Tenant Build-Out Work, to take all reasonable
steps to minimize interference with construction of the Mall Improvements and
any other construction, shall comply with the Site Logistics Procedures and the
Tenant Handbook, and shall jointly cause Tenants to repair any damage to the
Mall Improvements (or other work in the Building) caused by Mall II Buyer, the
Tenants or any contractors and subcontractors in the performance of the Tenant
Build-Out Work. In no event shall the Tenant Build-Out Work performed by the
Tenants or any of their respective contractors or subcontractors involve any
modification
21
to the Mall II Improvements (without the prior consent of Developer) or
otherwise adversely affect Developer's ability to obtain a temporary certificate
of occupancy or a certificate of occupancy (a "C of O") for any portion of the
Building. In the event that the performance of the Tenant Build-Out Work by
Tenant causes any delay in Developer obtaining a C of O for any portion of the
Building, such delay shall constitute a Construction Delay.
3.8 Substantial Completion; Acceptance Procedure.
(a) "Substantial Completion" is defined in Schedule "11"
attached hereto and made a part hereof.
(b) In addition to the Interim Substantial Completion Notices
described in the following Section 3.8(c), Developer shall give Mall II Buyer at
least ninety (90) days' prior notice of Developer's good faith estimate of the
date of the anticipated occurrence of Substantial Completion of all of the Mall
Improvements (the "Anticipated Completion Date"). When Developer determines that
Substantial Completion has occurred, Developer shall cause Developer's Architect
to prepare and submit to Mall II Buyer a list of remaining items to be completed
which it believes to be Punch List Items (as defined in Schedule "11") (a
"Proposed Final Checklist"). Within five (5) Business Days after Mall II Buyer's
receipt of the Proposed Final Checklist (the "Inspection Period"), Mall II Buyer
shall conduct one or more inspection(s) of the Mall Improvements. If Mall II
Buyer believes that Substantial Completion has not yet occurred, Mall II Buyer
shall give Developer notice during the Inspection Period specifying why Mall II
Buyer believes that Substantial Completion has not yet occurred and setting
forth with sufficient specificity a list of work that Mall II Buyer believes is
still required to achieve Substantial Completion (an "Exceptions Notice"). In
the event an Exceptions Notice is delivered, subject to Section 3.8(c) below,
Developer shall cure or correct the conditions or matters specified in the
Exceptions Notice and shall cause Developer's Architect to deliver another
Proposed Final Checklist. If Mall II Buyer still believes that Substantial
Completion has not occurred, Mall II Buyer shall give another Exceptions Notice,
and the same procedure shall be repeated until Mall II Buyer agrees (or the
Independent Expert in good faith determines) that Substantial Completion has
occurred. If Mall II Buyer agrees (or the Independent Expert in good faith
determines) that Substantial Completion has occurred, Mall II Buyer shall give
Developer a notice (a "Buyer's Proposed Final Checklist") during the Inspection
Period specifying items not included on the Proposed Final Checklist which
remain to be completed or corrected. For purposes of determining Developer's
obligations with respect to items specified on any Buyer's Proposed Final
Checklist, the term "Buyer's Proposed Final Checklist" shall mean the list of
Punch List Items submitted by Mall II Buyer in accordance with this subsection
as amended following resolution as provided hereby by Developer and Mall II
Buyer of any dispute with respect thereto. Following delivery of the Proposed
Final Checklist to Mall II Buyer by Developer and/or the Buyer's Proposed Final
Checklist to Developer by Mall II Buyer, as the case may be, then, subject to
Force Majeure delays, Developer shall cause to be completed the items set forth
in the Proposed Final Checklist and Buyer's Proposed Final Checklist, if any
(collectively, "Punch List Work") as soon as reasonably possible, and in all
events prior to the Opening Date, except to the extent
22
that minor items of Punch List Work that do not adversely effect the operation
of the Phase II Mall may be completed after the Opening Date. Developer's
indemnification in Section 3.5 and the insurance coverages set forth in Section
3.6 shall apply to all Punch List Work. Developer shall reimburse Mall II Buyer
or a Tenant, as applicable, for costs and expenses incurred by reason of any
damage caused by Developer or its contractors or subcontractors to the Tenant
Build-Out or any other property of Mall II Buyer or such Tenant.
(c) Prior to giving the Anticipated Completion Notice
described in Section 3.8(b) above, Developer may give interim substantial
completion notices (the "Interim Substantial Completion Notices") for portions
of the Mall Space as the same near Substantial Completion. The same procedure
set forth in Section 3.8(b) of delivery of a Proposed Final Checklist, followed
by an Exceptions Notice and then the Buyer's Proposed Final Checklist shall
apply following the delivery of any Interim Substantial Completion Notices.
(d) If Developer fails to commence the Punch List Work within
thirty (30) days after Substantial Completion of the entire Mall Improvements,
subject to Force Majeure, or if Developer does not thereafter diligently
prosecute such Punch List Work to completion, and if Mall II Buyer notifies
Developer that Developer is in default of its obligations to commence and
diligently prosecute the Punch List Work to completion and of Mall II Buyer's
intention to undertake the Punch List Work, then fifteen (15) days thereafter if
the Punch List Work is not completed or being diligently prosecuted to
completion by Developer, Mall II Buyer shall have the right (but not the
obligation) to undertake the Punch List Work itself (or through other Persons)
at Developer's expense; and if and to the extent that Mall II Buyer does so,
Developer shall pay upon demand the reasonable costs so incurred by Mall II
Buyer.
(e) Any dispute under this Section shall be submitted to the
Independent Expert for resolution. As to any matter so submitted, the time
periods specified in Sections 3.8(b) or 3.8(c) above shall be tolled until the
date a decision is reached or issued by the Independent Expert.
(f) The provisions of this Section 3.8 shall survive the
Closing.
ARTICLE 4
DESIGN OF BUILD-OUT OF PHASE II MALL
4.1 Design of Build-Out. Mall II Buyer and Developer will jointly
design the Landlord Build-Out, and Mall II Buyer and Developer will jointly
cause the Tenants to design the Tenant Build-Out of the Tenant Spaces, so that
the Phase II Mall will be a First-Class mall with a Xxxxxxx Hills/Rodeo Drive
theme and an upscale neo-classical style as provided in the Initial Plans.
Developer shall have the right to deal directly with Tenants and the Tenant's'
contractors to the extent necessary for the coordination of the Build-Out design
and construction.
23
4.2 Build-Out Design Submissions for Coordination. Developer will
coordinate the Tenant Build-Out with the construction of the Mall Improvements
and the Landlord Build-Out and Mall II Buyer and Developer will jointly
supervise Tenants to ensure that the Tenant Build-Out is performed in accordance
with the Initial Plans, the Final Construction Drawings and Specs, the Initial
Demising Wall Plan, the Final Demising Wall Plan, this Agreement, the
Construction Safety & Health Manual, the Tenant Handbook, the Site Logistics
Procedures, the Work Continuation Agreement, the REA or the Amended REA.
Developer shall have the right to review and approve, in its reasonable
judgment, the consultant or contractors agreements for any Build-Out Work for
which it is required to pay. Mall II Buyer shall endeavor to deliver, or cause
Tenants to deliver, such contracts to Developer.
ARTICLE 5
CONSTRUCTION OF BUILD-OUT
5.1 Construction of Build-Out. Developer will undertake the
construction of the Landlord Build-Out, including agreement, upon consultation
with Mall II Buyer, on the terms and conditions of any contracts to construct
the Landlord Build-Out. Developer will ensure that the Landlord Build-Out is
performed in accordance with the Initial Plans, the Final Construction Drawings
and Specs, the Initial Demising Wall Plan, the Final Demising Wall Plan, this
Agreement, the Site Logistics Procedures, the Construction Safety & Health
Manual, the guidelines of the Tenant Handbook set forth in Schedule "14"
attached hereto and made a part hereof, as the same may be modified to reflect
the theme and layout of the Phase II Mall and from time to time by Developer
(the "Tenant Handbook") and the Work Continuation Agreement set forth in
Schedule "20" attached hereto and made a part hereof. Developer will obtain at
its expense with regard to any Landlord Build-Out, and Developer and Mall II
Buyer will cause Tenants to obtain with respect to any Tenant Build-Out, all
permits and approvals for construction of the Tenant Build-Out other than the
Required Mall Improvement Permits (which Developer shall obtain at Developer's
expense). The Landlord Build-Out shall be constructed of good quality; in a
xxxxxxx-like manner and incorporating only new materials and equipment; and by
means and methods complying with applicable Legal Requirements and insurance
requirements. Developer shall commence the Landlord Build-Out Work, and Mall II
Buyer and Developer shall jointly cause Tenants to commence the Tenant Build-Out
Work no later than promptly after delivery of the Build-Out Notice, subject to
Force Majeure, Developer Delays, Construction Delays and the Site Logistics
Procedures. Developer shall be responsible to pay all Leasing Costs in
connection with the Landlord Build-Out.
5.2 Mall II Buyer's Indemnification.
(a) Mall II Buyer agrees (at Mall II Buyer's expense) to
indemnify, defend and hold harmless Developer and Mall II LLC (such
indemnification of Mall II LLC only prior to the assignment of the Membership
Interests to Mall II Buyer) and their respective directors, officers,
stockholders, partners, members, and
24
employees (the foregoing collectively the "Developer Indemnitees") from and
against loss, liability, damage, cost, or expense (including Fees and Costs)
which any of them may suffer, or which may be asserted against any of them, in
whole or in part by reason of, or in connection with: (i) any bodily injury,
sickness, disease or death of or to any person or persons, or any damage to or
destruction of property, arising out of or resulting from acts or omissions of
Mall II Buyer, Mall II LLC (to the extent taken or occurring after Closing), or
their respective contractors or subcontractors in connection with any act or
omission of any such party in respect of the Phase II Land or the Mall
Improvements; (ii) any failure by Mall II Buyer, Mall II LLC (to the extent
occurring after Closing), or their respective contractors or subcontractors to
comply with applicable Legal Requirements or insurance requirements; (iii) the
use or misuse by Mall II Buyer or Mall II LLC (to the extent occurring after
Closing) or their respective contractors or subcontractors of Hazardous
Materials on the Phase II Land or in the Leasehold Airspace; (iv) infringement
of patent rights, licensing or royalty agreements, or trade secrets by Mall II
Buyer or Mall II LLC (to the extent occurring after Closing), or their
respective contractors or subcontractors; and/or (v) any liens filed against the
Building and/or the Phase II Land or the Leasehold Airspace by any Person
claiming by, through, or under Mall II Buyer, Mall II LLC (to the extent
occurring after Closing) other than liens filed as a result of Developer's
failure to pay any Leasing Costs.
(b) Mall II Buyer shall defend any Legal Proceedings commenced
against any of Developer Indemnitees concerning any matter covered by the
foregoing indemnification. Mall II Buyer shall give Developer copies of
documents served in any such Legal Proceeding and shall advise Developer
regularly as to the status of the same. If Mall II Buyer fails to defend
diligently against any such Legal Proceeding, or if Developer reasonably
believes that Mall II Buyer's interest in such Legal Proceeding is adverse to
Developer's interest therein, Developer shall have the right (but not the
obligation), upon ten (10) Business Day's prior written notice, to defend the
same at Mall II Buyer's expense. Mall II Buyer shall not settle any such Legal
Proceeding without the written consent of Developer (unless such settlement
shall release each Developer Indemnitee against whom liability has been asserted
from all liability with respect to such Legal Proceeding without contribution
from such Indemnitee). No Developer Indemnitee may settle any such Legal
Proceeding without the written consent of Mall II Buyer, which shall not be
unreasonably withheld.
(c) Developer shall notify Mall II Buyer promptly of every
Legal Proceeding or claim which may be covered by the indemnification in (a)
above. Mall II Buyer's obligations under this Section 5.2 shall not be limited
or defined by the amount of insurance carried by Mall II Buyer or by limitations
on the amount or type of damages under worker's compensation acts or other laws
relating to employee benefits.
(d) This Section shall not require indemnification of any
Developer Indemnitee to the extent of the negligence or willful misconduct of
Developer, Mall II LLC (prior to the transfer of the Membership Interests to
Mall II Buyer), any of their respective agents or another Developer Indemnitee.
(e) The provisions of this Section 5.2 shall survive the
Closing.
25
5.3 Insurance Coverages. Mall II Buyer and Developer shall jointly
cause each Tenant with access to the Tenant Spaces to perform the Tenant
Build-Out to include Developer and Mall II LLC as additional insureds on each
policy of liability insurance carried by such Tenant, as applicable, with
respect to the Tenant Build-Out with a limit of not less than $10,000,000 with
respect to any Tenant. Mall II Buyer and Developer shall jointly cause each such
Tenant to furnish certificates evidencing all such insurance coverages to
Developer before such Tenant starts work in the Phase II Mall. Alternatively,
the parties may agree that Mall II Buyer, Mall II LLC and Developer may be
included as insureds under one or more liability policies covering the Build-Out
and the entire Building.
5.4 Site Logistics Procedures and Plan. Within a reasonable time
before Developer or a Tenant, as applicable, commences the Build-Out (so that
Mall II Buyer and Developer may plan and schedule site mobilization, logistics,
and materials deliveries), Developer shall promulgate procedures and a plan (the
"Site Logistics Procedures") for mobilization, logistics, and access applicable
to all Persons performing construction work or services in the Building,
including work hours; delivery, handling and storage of materials; staging,
hoisting, use of elevators and loading docks, location of trailers; and other
such matters. All Persons performing work in the Building shall be required to
abide by the Construction Safety & Health Manual described on Schedule "9"
attached hereto and made a part hereof, as the same may be modified by Developer
to reflect the Phase II Mall layout and other relevant facts (the "Construction
Safety & Health Manual") and either Developer or H/C I Owner may, from time to
time, update and revise the Construction Safety & Health Manual in its
reasonable discretion. The parties acknowledge that staging, hoisting, etc. may
need to be integrated into the design and is crucial to construction sequencing.
The Site Logistics Procedures: (a) shall not discriminate against any Tenant in
such matters; (b) shall afford any Tenant performing Tenant Build-Out Work
regular but non-exclusive use of hoists and elevators for orderly and regular
access to the areas of the Building in which Tenant will perform any Tenant
Build-Out; (c) shall allow any Tenant orderly and regular access to those areas
of the Building outside the Phase II Mall which such Tenant must access to
supervise or perform the Tenant Build-Out; and (d) shall allow for sufficient
facilities, equipment and access to permit the orderly and continuous
prosecution and completion of the construction of the Tenant Build-Out by
Tenants and the contractors and subcontractors of Tenants during normal working
hours (and on an overtime basis if a Tenant elects to perform work on an
overtime basis and other construction work is permitted on an overtime basis).
The Site Logistics Procedures shall specify that Developer will provide hoists
and operating engineers to operate hoists and service elevators (but only so
long as such docks, hoists and elevators are available for use as of such date).
However, notwithstanding the foregoing, the Site Logistics Procedures may
provide that, starting on a date prior to the opening for business of any
portion of the Phase II Hotel/Casino, the access of Tenants (and their
respective contractors' and subcontractors') for supervision and construction of
the Tenant Build-Out shall be limited to the loading docks, hoists and service
elevators (but only so long as such docks, hoists and elevators are available
for use as of such date). Developer shall not discriminate against the Tenants
in applying the Site Logistics Procedures or otherwise in Developer's
administration of construction
26
work on, or access to or through, the Building. The Site Logistics Procedures
shall not impose any cost or charge for access to or through, or use of, any
facilities or areas of the Building except for pass-through without markup of
actual labor, utility or equipment charges or other third-party costs
(collectively, "Direct Costs") for use of facilities as to which labor or
special equipment are required and are specifically chargeable to or paid by
Developer (including overtime where applicable). The costs of the hoists and
service elevators shall not be included in Direct Costs, except to the extent
which a Tenant requests overtime service. If direct hourly rates do not apply,
Developer shall pay, unless the applicable Tenant shall be required to pay, 100%
of Direct Costs for equipment and facilities used exclusively by any Tenant and
an equitable portion of Direct Costs for equipment and facilities also used by
others as and to the extent actually used by any Tenant based on such Tenant's
percentage of use of special equipment and facilities (including overtime where
applicable). Developer shall provide dumpsters for use in connection with the
Tenant Build-Out. Mall II Buyer shall be responsible for cleaning their own work
area and removing their own trash to the provided dumpsters. Each Tenant shall
pay for the dumpster service as a part of the Direct Costs in accordance with
their Tenant Space's proportionate percentage of the total leasable Floor Area.
5.5 Inspection by Developer. Developer shall have the right (and
Mall II Buyer and Developer shall endeavor to include such a right in the
Leases) during usual business hours, at Developer's expense and upon reasonable
notice to Mall II Buyer or Tenants, to inspect the Tenant Build-Out Work to
ascertain that the performance of such work adheres to the Leases and design
plans agreed to by Mall II Buyer, Developer and Tenants.
ARTICLE 6
ACCESS TO PHASE II LAND; RELATED MATTERS
6.1 Access. After the date hereof, Developer shall allow Mall II
Buyer and its Consultants, construction manager, contractors and representatives
to visit, inspect, and review the Phase II Land and the Building and matters
relating to the Phase II Land and the Building during working hours on Business
Days upon reasonable advance telephonic notice. Mall II Buyer's indemnification
in Section 5.2 and the insurance coverages set forth in Section 5.3 shall apply
to all inspections of the Phase II Land pursuant to this Article. In connection
with the joint leasing efforts described herein, Developer shall cooperate with
Mall II Buyer, including, without limitation, making available to Mall II Buyer
marketing materials with respect to the Phase II Hotel/Casino and (subject to
the provisions of this Section 6.1) permitting Mall II Buyer to conduct tours of
the Phase II Mall and the Phase II Hotel/Casino with prospective tenants.
Developer will also allow Mall II Buyer and its representatives (during working
hours on Business Days upon reasonable advance telephonic notice) to review and
copy information in Developer's possession (other than information which
Developer deems confidential) which may affect or relate to Mall II Buyer's
review or inspection of the design or construction of the Mall Improvements,
Mall II Buyer's participation in the design and construction of the Build-Out,
and/or Mall II Buyer's ownership and/or operation of the Phase II Mall after the
Closing or which Mall II Buyer may otherwise
27
reasonably request to confirm, verify or inquire into matters covered by this
Agreement, including the physical condition of the Phase II Land, plans,
surveys, title examinations, construction contracts, etc. Developer and
Developer's Consultants and representatives shall cooperate reasonably with Mall
II Buyer's Consultants and representatives in such matters. Any visits to, or
inspections at, the Phase II Land or the Building by Mall II Buyer or its
representatives shall not interfere with construction or other work in progress
and shall be subject to site safety concerns.
6.2 Indemnity. Mall II Buyer agrees to indemnify Developer from and
against loss, cost, expense, damage, charge, claim or liability (including Fees
and Costs) which Developer may suffer, incur, or pay out by reason of the acts
or omissions of Mall II Buyer and its Consultants and representatives in making
any inspections of the Phase II Land and the Building pursuant to Section 6.1
(but not with respect to any condition at the Phase II Land or the Building
discovered by any inspections, examinations or tests). Mall II Buyer and its
Consultants shall have liability insurance in effect which covers any activities
on the Phase II Land or in the Building before the Closing in accordance with
Section 6.1. The provisions of this Section 6.2 shall survive the Closing.
ARTICLE 7
TIMING FOR DESIGN AND CONSTRUCTION
7.1 Substantial Completion.
(a) Developer shall give Mall II Buyer quarterly updates of
the progress of construction of the Mall Improvements and the Palazzo Casino
Resort and monthly updates for the six (6) months immediately preceding the date
on which Developer expects to achieve Substantial Completion. Developer shall
achieve Substantial Completion by the date that is the earlier of (i) thirty-six
(36) months after the date on which sufficient permits are received to allow
Developer to begin construction in compliance with Legal Requirements and (ii)
March 1, 2008, as the same may be extended due to Force Majeure, Construction
Delays or Buyer Delays (the "Outside Substantial Completion Date"). In the event
that, despite Developer's diligent efforts, Substantial Completion has not
occurred by the Outside Substantial Completion Date and Developer shall
nevertheless be endeavoring diligently to complete the Mall Improvements, then
so long as Mall II Buyer is not in default of any obligations under this
Agreement, Mall II Buyer shall be entitled to liquidated damages (the "Interim
Liquidated Damages") in the amount of $5,000 per day for each day after the
Outside Substantial Completion Date on which Substantial Completion has not
occurred up to and including the date that is six (6) months after the Outside
Substantial Completion Date and $10,000 per day for each day from and after said
date to and including the date that is one (1) year after the Outside
Substantial Completion Date on which Substantial Completion has not occurred.
During the one year period during which Interim Liquidated Damages are payable,
Developer shall also reimburse Mall II Buyer for actual out-of-pocket damages
incurred and paid to Tenants under said Tenant's Leases (including any reduced
rent, rent abatements or other rent concessions under said
28
Tenant's Leases) resulting from Developer's delay in achieving Substantial
Completion ("Lease Damages").
(b) If Substantial Completion has not occurred on or before
the date that is one (1) year after the Outside Substantial Completion Date,
subject to extension for Force Majeure, Construction Delays and Buyer Delays,
then Mall II Buyer and Developer agree that it would be impracticable and
extremely difficult to ascertain the actual damage to Mall II Buyer as a result
of the failure of Developer to achieve Substantial Completion by such date and
that the Buyer Liquidated Damages Amount is a reasonable estimate of the damages
which Mall II Buyer will incur as a result of such failure and, in such an
event, Developer shall pay to Mall II Buyer the Buyer Liquidated Damages Amount
and Developer shall be responsible to pay the Lease Damages. The "Buyer
Liquidated Damages Amount" as used in this Agreement shall mean one hundred
million dollars ($100,000,000).
7.2 Opening Date.
(a) Commencing upon the notification from Developer to Mall II
Buyer of the Anticipated Completion Date as provided in Section 3.8, Mall II
Buyer and Developer shall negotiate in good faith, based on the work required to
complete the Phase II Mall and the Phase II Hotel/Casino, to agree on an
appropriate date for the Phase II Mall and the Phase II Hotel/Casino to open for
business (the "Opening Date"). Developer shall cause the Phase II Hotel Casino
to open for business no later than the Opening Date. "Open for Business" as used
in connection with the Phase II Hotel/Casino shall mean that the casino is open
for business to the general public and at least one thousand (1,000) guest rooms
are available for occupancy by hotel guests. The Opening Date shall be extended
one day for each day of delay due to Force Majeure, Construction Delays or Buyer
Delays. If Developer shall fail to cause the Phase II Hotel/Casino to Open for
Business by the Opening Date, as extended as described in the prior sentence,
Developer shall pay to Mall II Buyer the amount of $5,000 per day for each day
after the Opening Date on which the Phase II Hotel/Casino fails to Open for
Business up to and including the one hundred and eighty-first (181st) day
following the Opening Date and $10,000 per day for each day from the one hundred
and eighty-first (181st) day following the Opening Date through the one year
anniversary of the Opening Date on which the Phase II Hotel/Casino fails to Open
for Business. From and after the date that is one year after the Opening Date,
if the Phase II Hotel/Casino is not Open for Business, Developer shall reimburse
Mall II Buyer for any actual damages incurred as a result of the delayed opening
for business of the Phase II Hotel/Casino.
(b) Mall II Buyer shall use commercially reasonable efforts to
cause the Phase II Mall to Open for Business on the Opening Date, but in no
event shall the Phase II Mall Open for Business later than the latest of (i)
four (4) months after the date on which Substantial Completion is achieved, (ii)
the date on which the Phase II Hotel/Casino opens for business or (iii) the
Opening Date (the "Mall Opening Date"). "Open for Business" as used in
connection with the Phase II Mall shall mean that the Phase II Mall has held a
public grand opening. The Mall Opening Date shall be extended one day for each
day of delay due to Force Majeure or Developer Delays. If Mall II
29
Buyer shall fail to cause the Phase II Mall to Open for Business by the Mall
Opening Date, as extended as described in the prior sentence, Mall II Buyer
shall reimburse Developer for any actual damages incurred as a result of the
delayed opening for business of the Phase II Mall.
(c) The provisions of this Section 7.2 shall survive the
Closing.
ARTICLE 8
AMENDED REA AND XXXXX
8.1 Amended REA. The Phase II Mall is part of a complex consisting
of the Venetian Casino Resort and the Palazzo Casino Resort. The Venetian Casino
Resort and the Palazzo Casino Resort each include several component sections
each owned by a different Unit Owner. The REA is the document that governs the
relationship, including, among other things, cost allocations and easements,
among the various Unit Owners. Prior to the Closing, Developer, Mall II Buyer
and the other Unit Owners shall prepare an amendment and/or restatement of the
REA to be entered into by and among the Unit Owners (the "Amended REA") to
reflect the construction of the Palazzo Casino Resort and the acquisition of the
Membership Interests by Mall II Buyer. Negotiations regarding the Amended REA
will follow as soon as practicable following the date hereof and each of
Developer and Mall II Buyer must act in good faith and reasonably in connection
with such negotiations. The Amended REA shall amend the terms of the REA to
provide for, among other things, (i) appropriate mutual operating covenants,
(ii) joint marketing and advertising, (iii) certain shared casino or mall
operations, (iv) the sharing of customer information, (v) the joint purchasing
of insurance, (vi) shared security operations, (vii) easements, encroachments
and other similar rights necessary or desirable for the operation of the various
components of the Venetian Casino Resort and the Palazzo Casino Resort, (viii) a
requirement that Mall II LLC pay its share of those common maintenance, utility
costs and other items as set forth on Schedule "15 attached hereto and made a
part hereof (subject to variables set forth in Schedule "15), (ix) parking, (x)
that Mall I Buyer shall cause the governing documents between Mall I LLC and
Mall I Buyer and their respective lenders to provide that Developer and its
Affiliates are permitted transferees of Mall I LLC's interest in the Phase I
Mall or Mall I Buyer's interest in Mall I LLC and that Developer or any of its
Affiliates shall be permitted to assume such financing in connection with the
exercise by Developer of its rights under Section 21.2 and (xi) any other
matters that would be of mutual benefit to the Unit Owners. In the event that
the Unit Owners are not able to agree on the terms of the Amended REA the matter
shall be referred to an Independent Expert in accordance with the provisions of
Article 9.
8.2 XXXXX. No later than thirty (30) days prior to the opening of
the Phase II Mall, unless Mall I LLC and Mall II LLC agree otherwise, there must
be in place an executed construction, operation and reciprocal easement
agreement ("XXXXX") between Mall I LLC and Mall II LLC. Negotiations regarding
the XXXXX will follow as soon as practicable following the date hereof and each
of Mall I LLC and Mall II LLC must act in good faith and reasonably in
connection with
30
such negotiations. The XXXXX must, among other things, (i) be an agreement that
a commercially reasonable owner of the Phase I Mall and of the Phase II Mall
would execute, (ii) provide that, unless the prior written consent of Mall I LLC
has been obtained, the Phase II Mall shall not contain more than five hundred
thousand (500,000) square feet of gross leasable area, (iii) contain guidelines
relating to the design of the Phase II Mall (including, without limitation, the
connection(s) between the Phase I Mall and the Phase II Mall), and relating to
alterations and maintenance of the Phase I Mall and the Phase II Mall, so that,
among other things, the malls are architecturally harmonious and constructed and
maintained in a first-class manner, (iv) provide for the joint maintenance,
leasing, marketing, management and operation, of the Phase I Mall and the Phase
II Mall, (v) require each of Mall I LLC and Mall II LLC to pay (A) all operating
and other expenses that are directly allocable to either mall and (B) an
equitable portion of all operating and other expenses that are not directly
allocable to either mall but otherwise relate to the "integrated mall" ("Shared
Mall Expenses"), (vi) provide for approval of a leasing plan and, with respect
to all operating expenses that should appropriately be Shared Mall Expenses, an
operating budget prior to commencement of operation of the Phase II Mall and
each year thereafter, (vii) provide that each of Mall I LLC and Mall II LLC is
entitled to receive and retain, for its own account, all revenue generated by
the Phase I Mall or the Phase II Mall, as applicable, (viii) allow each of Mall
I LLC and Mall II LLC to sell and finance its mall and, in connection therewith,
to assign or mortgage its interest in the XXXXX, (ix) provide for the granting
of appropriate easements across each of the Phase I Mall and the Phase II Mall,
(x) contain provisions relating to restoration of the Phase I Mall and the Phase
II Mall after casualty and condemnation, (xi) contain a mechanism to resolve
disputes under the XXXXX and (xii) require Mall II LLC to grant to Mall I LLC an
easement for the location and operation by Mall I LLC of the gondola ride
through certain areas of the Phase II Mall. In the event that Mall I LLC and
Mall II LLC are not able to agree on the terms of the XXXXX the matter shall be
referred to an Independent Expert in accordance with the provisions of Article
9.
ARTICLE 9
CONSULTATION; DISPUTE RESOLUTION
9.1 Consultation; Mall II Buyer's Site Representative. The parties
will consult with each other regularly concerning the evolving design,
respectively, of the Mall Improvements and of the Build-Out and also of the
construction of the Mall Improvements and the Build-Out while in progress. For
this purpose the parties shall exchange drawings, specifications, shop drawings,
submittals, excerpts of meeting minutes, and other materials that may be
necessary or appropriate to further the purposes of this Agreement. Mall II
Buyer shall appoint a representative who shall be assigned full time to the
Phase II Mall as the on-site representative of Mall II Buyer (the "Mall II Buyer
Site Representative"). The Mall II Buyer Site Representative shall be the
primary point of contact between Developer and Mall II Buyer as to the matters
contemplated by this Agreement, including, without limitation, the delivery of
the Mall II Buyer Monthly Statement, the development of the Common Area Plans,
the Initial Demising Wall Plan and the Final Demising Wall Plan, coordinating
the Tenant Build-
31
Out Work by the Tenants, their contractors and subcontractors and any requested
changes to the Final Construction Drawings and Specs, the Initial Demising Wall
Plan, the Final Demising Wall Plan, the Standards Document or the Common Area
Plans. The Mall II Buyer Site Representative shall have authority to make
decisions and execute agreements in regard to the Phase II Mall, and to exercise
any rights of Mall II Buyer under this Agreement, on behalf of Mall II Buyer and
Developer shall be entitled to rely on any instructions, consents or approvals
given by the Mall II Buyer Site Representative as if they are the instructions
of Mall II Buyer. Each party may invite representatives of the other (including
the Mall II Buyer Site Representative) from time to time, to attend such party's
regular job or project meetings to discuss matters of interest or concern. This
Section shall not require disclosure of confidential or sensitive materials or
require attendance at meetings in which disputes with the other party,
unresolved positions, or matters not involving the other party are to be
discussed.
9.2 Resolution of Disputes.
(a) In the event there is a dispute among any of the parties
(the "Disputing Parties") regarding the amount of any Interim Payment and the
Disputing Parties cannot, with respect to such dispute, resolve such dispute
prior to the time set forth for payment of such Interim Payment, then the matter
in question shall be resolved in accordance with the further provisions of this
Section 9.2(a). In the event of any such disagreement, Developer and Mall II
Buyer shall promptly notify the Independent Expert (as defined below) of such
disagreement and of their desire that such disagreement be resolved by the
Independent Expert. Developer and Mall II Buyer shall each present to the
Independent Expert the amount they believe to be the correct amount of the
Interim Payment in dispute and any documentation necessary to support such
position. The Independent Expert may only decide in favor of the amount
presented by either Developer or Mall II Buyer, and may not make a
ruling/determination other than in favor of one of the two amounts presented.
(b) In the event that there is a dispute among the Disputing
Parties that this Agreement provides will be resolved by an Independent Expert
arising out of or relating to this Agreement, other than those disputes in
regard of the amount of any Interim Payment described in Section 9.2(a) above.
and the Disputing Parties cannot, with respect to any such dispute, resolve such
dispute within the time period set forth in Section 9.3 of this Agreement, then
the matter(s) in question shall be resolved in accordance with the further
provisions of this 9.2(b). In the event of any such disagreement, the Disputing
Parties shall promptly notify the Independent Expert (as defined below) of such
disagreement and of their desire that such disagreement be resolved by the
Independent Expert. The Independent Expert shall be instructed to render its
decision within the time period set forth in Section 9.3 below after such
notification. Each of the Disputing Parties shall be entitled to present
evidence and arguments to the Independent Expert, which evidence and arguments
may include the relevant provisions hereof. During the pendency of such
dispute-resolution procedure, the Disputing Parties shall continue their
performance under this Agreement, including with respect to the matter that is
the subject of such procedure. The determination of the Independent Expert
acting as above provided (i) shall be conclusive and binding upon the
32
parties to this Agreement and (ii) shall in no event modify, amend or supplement
this Agreement in any manner. The Independent Expert shall be required to give
written notice to the Disputing Parties stating its determination, and shall
furnish to each party to this Agreement a signed copy of such determination.
Each of the Disputing Parties shall pay half of the fees and expenses of the
Independent Expert and all other expenses of the above-described dispute
resolution procedure (not including the attorneys' fees, witness fees and
similar expenses of the Disputing Parties, which shall be borne separately by
each of the Disputing Parties).
9.3 Submission of Disputes to Independent Expert.
(a) Submissions on an Expedited Basis. Disputes referred to
the Independent Expert pursuant to the terms of this Agreement which are
reasonably likely to cause a delay in Substantial Completion, other than the
determination of Substantial Completion itself which shall be made in accordance
with Section 3.8, may be submitted for determination by an Independent Expert on
an expedited basis at any time if the Disputing Parties have been unable to
settle such dispute. The Independent Expert shall deliberate on an expedited
basis on such matters and shall render its decision within five (5) Business
Days after notification of the dispute. If the Independent Expert notifies the
Disputing Parties that it is impracticable to make a determination of such
dispute within such five (5) Business Day period, the deadline for the rendering
of a decision shall be extended as long as necessary as the Independent Expert
proceeding diligently shall take to resolve such dispute. Notwithstanding the
submission of such disputes to the Independent Expert, the Disputing Parties may
proceed with construction in regard to the disputed matter in the manner in
which Developer (in connection with disputes regarding Substantial Completion,
the Mall Improvements or the Landlord Build-Out) has determined, in good faith,
is appropriate and in compliance with this Agreement. If the Independent Expert
determines that one of the Disputing Parties has proceeded in a manner that is
in breach of the terms of this Agreement, such party shall be liable to the
other for all loss, liability, damage, cost, or expense (including Fees and
Costs) which the other party may suffer, or which may be asserted against such
party arising from such breach.
(b) Submissions on an Ordinary Basis. In any matter other than
those set forth in Section 9.3(a) above that this Agreement specifies shall be
resolved by an Independent Expert, in the event that the Disputing Parties
cannot, without respect to any such dispute, resolve such dispute (a) by the
Closing Date, the applicable Interim Payment Date, the Earn-Out Date or the
Final Date, with respect to disputes regarding the Closing Payment, any
Adjustment Payment, the Earn-Out Payment or the Recalculated Earn-Out,
respectively, or (b) within thirty (30) days, then the matter(s) in question
shall be resolved in accordance with Section 9.2. The Independent Expert shall
be instructed to render its decision within thirty (30) days (or any shorter
time reasonably agreed to by the Disputing Parties) after such notification.
9.4 Identity of Independent Expert. As used herein, the "Independent
Expert" shall mean (a) with respect to any dispute pertaining to architectural,
construction or engineering matters, an appropriately licensed and/or
33
registered (as applicable), reputable and independent architect or engineer; (b)
with respect to any dispute pertaining to hotel, casino, restaurant or retail
complex operation or management, a reputable and independent Person with
experience in pertinent commercial real estate operation and management; and (c)
with respect to any other dispute, a licensed, reputable and independent
certified public accountant, in each of (a), (b) or (c) reasonably acceptable to
the Disputing Parties. In all events, the Independent Expert shall (i) not be
affiliated with Developer, Mall II LLC or Mall II Buyer (or any Affiliate of any
of them) and (ii) have at least ten (10) years of relevant experience and
expertise with respect to large commercial real estate projects in Las Vegas,
Nevada and/or Xxxxx County, Nevada. In the event that Developer and Mall II
Buyer can not agree on the selection of an Independent Expert to resolve
disputes under Section 9.2(a) or (b) above, each of Developer and Mall II Buyer
shall choose an individual who satisfies the Independent Expert requirements of
this Section 9.4. Those individuals so chosen shall confer in good faith to
select a third individual who shall be the Independent Expert for the purposes
of this Agreement and the choice so made shall be binding on Mall II Buyer and
Developer. Proceedings before or involving dispute resolution under this Article
in and of themselves shall not constitute events of Force Majeure.
9.5 The provisions of this Article 9 shall survive the Closing.
ARTICLE 10
MALL II BUYER CONDITIONS
10.1 Conditions to Mall II Buyer's Obligations. Mall II Buyer's
obligation to consummate the Closing under this Agreement shall be subject to
satisfaction of each of the following conditions at or before the Closing:
(a) Developer shall have caused a commercial subdivision of
the Palazzo Casino Resort in order to cause the Phase II Mall and the Phase II
Hotel/Casino to become legal parcels which are separate and distinct from each
other and from the Phase II Land capable of being conveyed in fee simple.
(b) Developer shall have formed Mall II LLC and conveyed
Developer's fee interest in the Fee Mall Space and Developer's leasehold
interest in the Leasehold Mall Space to Mall II LLC.
(c) Substantial Completion shall have occurred.
(d) Title Insurer shall be willing to issue an owner's policy
of title insurance in the amount of the Closing Payment, subject to payment of
premiums, insuring fee title to the Fee Mall Space and leasehold title to the
Leasehold Mall Space and the Casino Shops as being vested in Mall II LLC, free
of Encumbrances other than Permitted Encumbrances, which policy shall include a
non-imputation endorsement in Title Insurer's standard form and reasonably
acceptable to Mall II Buyer.
34
(e) Developer shall have executed and delivered to Mall II
Buyer an Assignment of the Membership Interests in a form reasonably acceptable
to Mall II Buyer.
(f) All representations and warranties of Developer (without
reference to any modifications thereof contained in Developer's Representation
Certificate) contained in this Agreement that are required to be true, correct
and complete as of the Closing Date shall be true, correct and complete in all
material respects subject, however, to matters known to Mall II Buyer as of the
date hereof.
(g) Developer shall not be in default in any material respect,
as of the Closing Date, under Developer's covenants, agreements and undertakings
on behalf of itself or Mall II LLC in this Agreement.
(h) Developer shall have executed and delivered all Closing
Instruments required to be executed and delivered by Developer at or prior to
the Closing.
(i) Developer or H/C I Owner shall have obtained such
insurance coverage, if any, that it is required to obtain pursuant to the terms
of the Amended REA; and if and to the extent that such policy is not yet
effective, Developer shall have in force a policy of builder's risk insurance
which shall cover the Mall Improvements until such time as the foregoing
insurance coverage required by the Amended REA becomes effective. In either
case, a certificate of such policy shall have been delivered to Mall II Buyer.
(j) There shall exist no Hazardous Materials in or on the
Phase II Land or the Development that would prevent Use and Occupancy of the
Phase II Mall and/or the Common Elements by Mall II Buyer.
(k) No petition for relief or similar Legal Proceeding has
been filed (unless dismissed within 60 days) pursuant to the United States
Bankruptcy Code with respect to Mall II LLC or the Developer and there shall be
no binding injunction, order or judgment of any court having proper jurisdiction
prohibiting Mall II Buyer from consummating the Closing.
(l) Developer shall have delivered a certificate stating that
it is not a "foreign person" within the meaning of Section 1445 of the Internal
Revenue Code, as amended.
(m) Developer and Mall II LLC shall have entered into the
Master Lease Agreement and a memorandum thereof in recordable form shall have
been delivered to the Title Insurer for recording.
(n) Las Vegas Asia Corp.("Tsunami") shall have surrendered its
leasehold interest in the Phase I Mall and shall have delivered possession of
such space to Mall I LLC if the same is required pursuant to Section 15.14 of
this Agreement.
35
(o) Mall II LLC shall have received from each lender holding a
mortgage encumbering the fee interest in the Casino Shops an executed
subordination, non-disturbance and attornment agreement (the "SNDA") in form
reasonably acceptable to Mall II Buyer, with respect to the Master Lease
Agreement. Developer hereby agrees to use commercially reasonable efforts to
obtain such SNDA from any such lender.
(p) All exterior barricades, lifts and hoists shall have been
removed to the extent that the same interfere with the Phase II Hotel/Casino
and/or the Phase II Mall being Open for Business, the Phase II Automobile
Parking Area shall be open and all building systems in the Phase II Mall
(including, without limitation, HVAC and life and safety) shall have been tested
and verified as being in working order.
(q) All Tenant Payments held by Developer pursuant to Section
16.3(c), if any, shall be transferred to an account maintained in the name of
Mall II LLC.
(r) The Phase II Hotel/Casino shall be Open for Business.
(s) Any other condition to Mall II Buyer's obligations which
are specifically set forth in this Agreement shall have been fulfilled.
ARTICLE 11
DEVELOPER CONDITIONS
11.1 Conditions to Developer's Obligations. The obligations of
Developer to be performed at the Closing shall be subject to satisfaction of the
following conditions:
(a) All representations and warranties of Mall II Buyer in
this Agreement shall be true, correct, and complete in all material respects as
of the Closing Date.
(b) Mall II Buyer shall not be in default in any material
respect, as of the Closing Date, under any covenant, agreement or undertaking of
Mall II Buyer under this Agreement.
(c) Mall II Buyer shall have executed and delivered all
Closing Instruments required to be executed and delivered by Mall II Buyer at or
prior to the Closing.
(d) Mall II Buyer shall have delivered the Closing Payment to
Developer as set forth in Section 20.2(a) of this Agreement.
(e) Any other conditions to Developer's obligations which are
specifically set forth in this Agreement shall have been fulfilled.
36
ARTICLE 12
WAIVER OF CONDITIONS
12.1 Mall II Buyer's Waiver. Mall II Buyer shall have the right to
waive compliance by Developer and/or any other party with any condition set
forth in Article 10.
12.2 Developer's Waiver. Developer shall have the right to waive
compliance by Mall II Buyer of any condition set forth in Article 11.
12.3 Written Waiver. Any waiver under Section 12.1 or 12.2 must be
in writing and must refer specifically to the condition being waived. If the
Closing occurs, the conditions in Articles 10 and 11 shall be deemed to have
been satisfied unless specified to the contrary in writing, whether or not
specifically waived; provided, however, that neither party shall be released
from any obligations which survive the Closing.
12.4 Notice by Developer. Subject to Section 15.12, if, before the
Closing Date, either party becomes aware that any of Developer's representations
and warranties in this Agreement are untrue, incorrect, or incomplete in any
material respect (provided that such representations and warranties were true,
correct and complete when originally made), such party shall give notice to the
other party as promptly as practicable. Thereafter, Developer shall have the
right to cure or correct the problem prior to the Closing Date.
12.5 Notice by Mall II Buyer. Subject to the last two sentences of
Section 16.1, if, before the Closing Date, either party becomes aware that any
of Mall II Buyer's representations and warranties in this Agreement are untrue,
incorrect or incomplete in any material respect (provided that such
representations and warranties were true, correct and complete when originally
made), such party shall give notice to the other party as promptly as
practicable. Thereafter, Mall II Buyer shall have the right to cure or correct
the problem prior to the Closing Date.
12.6 Covenant to Satisfy Conditions. Developer and Mall II Buyer
each hereby agree to use commercially reasonable efforts to cause each of the
conditions precedent to the obligations of the other party to be fully
satisfied, performed and discharged on and as of the Closing Date, except that
neither party shall have any obligation to expend any funds or incur any
liabilities or obligations which it would not otherwise be required to spend or
incur under the provisions of this Agreement.
37
ARTICLE 13
CLOSING
13.1 The Closing. The Closing shall take place at the offices of
Developer's counsel (or at another location in Xxxxx County, Nevada or New York
City, New York designated by Developer) at 10 am on the Mall Opening Date, time
being of the essence (the "Closing Date").
13.2 Delivery of Possession. Developer shall deliver possession of
the Phase II Mall to Mall II Buyer at the Closing (if Mall II Buyer is not
already in possession), subject only to the Permitted Encumbrances, the Site
Logistics Procedures and this Agreement.
ARTICLE 14
CLOSING DELIVERIES; RELATED MATTERS
14.1 Developer's Deliveries. Subject to the terms of this Agreement,
Developer shall execute and deliver to Mall II Buyer or Mall II LLC, as
applicable, at or prior to the Closing:
(a) an assignment of the Membership Interests to Mall II Buyer
(the "Assignment");
(b) a General Assignment/Xxxx of Sale assigning to Mall II LLC
the Exclusive Mall Equipment;
(c) the Amended REA;
(d) the Developer's Representation Certificate;
(e) the Developer's Warranty, if applicable;
(f) notices to Tenants from the appropriate parties informing
them of the termination of any lockbox agreements in effect immediately prior to
the Closing and instructing Tenants to pay rent in such a manner as directed by
Mall II Buyer;
(g) Developer's copies of any Leases executed by Mall II LLC
and Tenants;
(h) Developer's copies of any Service Contract that shall
survive the Closing;
(i) all sales tax, transfer tax and other tax returns, if any,
which the Developer is required by law to execute and deliver, either
individually or together
38
with Mall II Buyer, to any Government Authority as a result of the sale of the
Membership Interests;
(j) All records and files which are in the possession of the
Developer relating to the operation and maintenance of the Phase II Mall,
including without limitation, to the extent in the possession of Developer,
current tax bills, current water, sewer, utility and fuel bills, payroll
records, billing records for Tenants, Tenant files, repair and maintenance
records and the like which affect or relate to the Phase II Mall, plans,
drawings, blue prints and specifications for the Phase II Mall, certificates of
occupancy and other licenses and permits and keys to the Phase II Mall; and
(k) any other instruments or documents to be executed and/or
delivered by Developer pursuant to Schedule "7" or other provisions of this
Agreement.
14.2 Mall II Buyer's Deliveries. Subject to the terms of this
Agreement, Mall II Buyer shall execute and/or deliver to Developer at or prior
to the Closing:
(a) the Closing Payment;
(b) the Amended REA;
(c) All sales tax, transfer tax and other tax returns, if any,
certificates of value and similar documents which Mall II Buyer is required by
law to execute and deliver, either individually or together with Developer to
any Government Authority as a result of the purchase of the Membership
Interests.
(d) Counterparts of each of the instruments and documents
listed in Section 14.1 for which Mall II Buyer's execution is necessary to give
effect to such instrument or documents;
(e) Any payment for change costs required pursuant to Sections
3.3(b) or 3.3(c); and
(f) any instruments or documents to be executed and/or
delivered by Mall II Buyer pursuant to Schedule "7" or any other provisions of
this Agreement.
14.3 Utility Deposits and Escrows. If applicable, at the Closing,
Developer shall assign to Mall II LLC all deposits or escrows held for
Developer's account at or by any public utility company in connection with
public utility services furnished solely to the Phase II Mall. Mall II LLC shall
pay, or Developer or Mall II Buyer shall cause Mall II LLC to pay, to Developer,
at the Closing, for the amount of the deposits or escrows so assigned and will
become responsible for public utility charges due thereafter with respect to the
Phase II Mall. Alternatively, Developer may terminate such public utility
accounts. Prior to the Closing Date, Developer shall notify all such public
utility companies in writing (with copies to Mall II LLC) of the applicable
transfer of service.
39
14.4 Delivery of Phase II Mall Documents. At the Closing subject to
the terms of this Agreement, Developer shall deliver to Mall II LLC Developer's
originals (or, if Developer has no originals, true and complete copies) of the
Phase II Mall Documents; provided, however, that to the extent certain of the
operating manuals that constitute the Phase II Mall Documents are not available
to Developer at the time of Closing, Developer shall deliver them to Mall II
Buyer as promptly as possible thereafter.
14.5 Performance of Covenants and Responsibilities. At the Closing,
Developer shall keep and perform all covenants and responsibilities to be
performed at the Closing under this Agreement by Developer or by Mall II LLC.
14.6 Delivery of Survey. At Developer's expense, Developer shall
deliver to Mall II LLC, at the Closing, an "as-built" survey (dated or updated
to a date not earlier than sixty (60) days before the Closing Date) which shows
the Phase II Mall as constructed within the Building at the point of
construction as of such date. Upon completion of construction of the
Development, Developer shall deliver a final version of such survey, showing the
Development "as-built."
14.7 Approvals, etc. Developer shall use commercially reasonable
efforts to obtain or complete, as applicable, all approvals, authorizations,
consents or other actions by or filings with any Person (if any) which are
required to be obtained or completed by Developer prior to or in connection with
the execution and delivery of this Agreement or any of the Closing Instruments
or in connection with any other action required to be taken by Developer
hereunder at or before the Closing, including those listed in Schedule "6" (if
any), shall have been obtained or completed, as the case may be; however, it
shall not be a condition to Mall II Buyer's obligations under this Agreement
that any such approval, authorization or consent shall be obtained, but
Developer shall be obligated to pay and indemnify Mall II Buyer from and against
any damages, penalties or other sums that may be payable to the other Party by
reason of Developer's failure to obtain such consent, which obligations shall
survive the Closing.
ARTICLE 15
REPRESENTATIONS AND WARRANTIES
OF DEVELOPER; CERTAIN AGREEMENTS
15.1 Representations and Warranties of Developer. Developer
represents and warrants to Mall II Buyer as follows:
(a) The representations and warranties of Developer set forth
in Schedule "10," Part One attached hereto and made a part hereof, regarding its
organization and ownership, authorization of this Agreement and other matters,
are true and correct as of the date hereof. The representations and warranties
of Developer set forth in Schedule "10," Part Three attached hereto and made a
part hereof, regarding the organization and ownership of Mall II LLC,
authorization of this Agreement on behalf of Mall II LLC and other matters,
shall be true and correct as of the Closing Date.
40
(b) Except as set forth in Schedule "6," there are no
approvals, authorizations, consents or other actions by or filings with any
Person which are required to be obtained or completed by Developer in connection
with the execution and delivery of this Agreement or any of the Closing
Instruments or in connection with any other action required to be taken by
Developer hereunder at or before the Closing.
(c) Except as set forth in Schedule "6," to Developer's actual
knowledge, there are no outstanding judgments, orders, writs, injunctions or
decrees of any Government Authority, no pending Legal Proceedings, and no
proceedings to foreclose any Mortgage, security instrument, lien or other claim,
in each case, against Developer in connection with the Phase II Land or the
Development.
(d) Developer has received no written notice of any taking, or
proposed taking, of the Phase II Land or the Phase II Mall in Condemnation
(excluding sidewalk or street takings).
(e) Except as set forth on Schedule "18," attached hereto and
made a part hereof, Developer has not entered into any leases with respect to
the Phase II Mall and no third party has any right, option or election to rent
space in the Phase II Mall.
(f) Developer is not a "foreign person" within the meaning of
Section 1445 of the Internal Revenue Code, as amended.
(g) With respect to the Membership Interests and Mall II LLC:
(i) The Membership Interests shall constitute all of the
membership and management interests in Mall II LLC at all times after the
formation of Mall II LLC.
(ii) Developer will upon completion, and as of the
Closing Date, deliver to Mall II Buyer a true, correct and complete copy of the
limited liability company agreement and certificate of formation of Mall II LLC,
as amended. Developer and Mall II Buyer shall consult as to the form of limited
liability company agreement of Mall II LLC and Mall II Buyer shall have
reasonable approval rights as to the form of such Agreement except to the extent
that certain provisions are required by a lender in order to obtain the
necessary financing for the development, which provisions shall not require Mall
II Buyer's consent.
(iii) As of Closing, the Membership Interests shall be
owned by Developer, free and clear of all liens, security interests, options and
encumbrances and have not been pledged or hypothecated as of the date hereof to
any third party (except for any pledge or hypothecation that will be released at
or prior to Closing Date). Neither Developer nor Mall II LLC will grant, issue
or enter into and neither Developer nor Mall II LLC will be bound by any
options, rights, commitments, agreements, arrangements or undertakings of any
kind (other than this Agreement) which will obligate or could obligate Developer
or Mall II LLC to transfer the Membership Interests or any part thereof or
interest therein or grant to any other person or entity any voting, management
or other right in respect of the Membership Interests.
41
(iv) Mall II LLC will pay all Impositions and other
federal, state and local taxes as they become due.
(v) Mall II LLC will elect to be taxed as a partnership.
(h) With respect to the REA:
(i) Schedule "12" attached hereto and made a part hereof
is a true, correct and complete, but non-executed, copy of the REA.
(ii) As of the date hereof, the REA is in full force and
effect, and Developer has not received written notice from any party to the REA
that Developer has defaulted in performing any of its material obligations under
the REA. To Developer's knowledge, as of the date hereof, no material default
exists under the REA on the part of any of the parties thereto.
(iii) There are no unpaid obligations of Developer due
and payable under or in respect of the REA.
15.2 Mortgages. Developer shall pay and discharge at or prior to the
Closing any and every Mortgage against the Mall II Unit (and no Mortgage shall
constitute a Permitted Encumbrance).
15.3 Service Contracts. At or prior to the Closing, Developer shall
terminate all Service Contracts (effective as of the soonest possible date),
other than those listed on Schedule "4" attached hereto and made a part hereof
and any other Service Contract which Mall II Buyer elects in its sole discretion
by notice on or before sixty (60) days prior to Closing to have Mall II LLC
assume. Developer shall pay all termination costs in connection therewith.
15.4 Employees. Developer will have no employees engaged in the
operation, management, or repair of the Building who are required to become
employees of Mall II Buyer or Mall II LLC at or after the Closing. Mall II LLC
will not have employees at any time, without the prior written consent of Mall
II Buyer, not to be unreasonably withheld or delayed.
15.5 Title. Developer will have good title (free of Encumbrances
other than Permitted Encumbrances) to all items of Exclusive Mall Equipment on
the Closing Date. Developer will own and have full authority to use the Phase II
Mall Documents and to transfer the same to Mall II LLC as set forth in this
Agreement.
15.6 Hazardous Materials. Developer shall provide Mall II Buyer with
a copy of reports, inspections, or analyses concerning the presence (or possible
presence) of Hazardous Materials in or on the Phase II Land or the Building
which Developer commissions or receives with reasonable promptness after receipt
42
thereof. If requested by Developer, Mall II Buyer shall reimburse Developer for
the reasonable costs of copying such documents for Mall II Buyer.
15.7 Legal Proceedings. Developer shall notify Mall II Buyer of any
Legal Proceedings against Developer in connection with the Phase II Land or the
Development (other than "slip and fall" or similar Legal Proceedings covered by
insurance or other Legal Proceedings which will not adversely affect Developer's
ability to convey the Membership Interests to Mall II Buyer or performance of
Developer's obligations under this Agreement), or any notice of Condemnation (or
proposed Condemnation) of the Phase II Land or the Building in each case
promptly after receipt of the same (and upon request Developer shall provide
Mall II Buyer with copies of relevant documents to the extent in Developer's
possession).
15.8 Liens. Developer shall bond or otherwise discharge of record,
at Developer's expense, any liens filed against the Phase II Mall before or
after the Closing by any contractor or subcontractor of Developer (or any other
Persons claiming through or under Developer).
15.9 No Implied Representations. Mall II Buyer acknowledges that
except as expressly set forth in this Agreement, neither Developer nor any agent
or representative or purported agent or representative of Developer has made,
and Developer is not liable for or bound in any manner by, any express or
implied warranties, guaranties, promises, statements, inducements,
representations or information (including, without limitation, any information
set forth in materials heretofore furnished to Mall II Buyer by Xxxxxxx Xxxxx)
pertaining to the Mall Improvements, the Phase II Mall, the Palazzo Casino
Resort or any part thereof, the physical condition thereof, environmental
matters, income, expenses or the operation thereof, the uses which can be
lawfully made of the same under applicable zoning or other laws or any other
matter or thing with respect thereto. Without limiting the foregoing, Mall II
Buyer acknowledges and agrees that, except as expressly set forth in this
Agreement, Developer is not liable for or bound by (and Mall II Buyer has not
relied upon) any verbal or written statements, representations, or offering
materials or any other information respecting the Phase II Mall or the Palazzo
Casino Resort furnished by Developer or any broker, employee, agent, consultant
or other person representing or purportedly representing Developer. If Developer
or its agents have delivered or hereafter deliver to Mall II Buyer or its agents
any information, report, survey, analysis or similar documentation prepared by a
third party unrelated to Developer, Developer neither expressly or impliedly
warrants or represents to Mall II Buyer the truth, accuracy or completeness
thereof and expressly disclaims any liability whatsoever with respect thereto or
any obligation independently to investigate the matters contained therein; and
Mall II Buyer hereby acknowledges that Developer has or is providing such
information, reports, surveys, analysis or other third-party documents to Mall
II Buyer as an accommodation only and that Mall II Buyer shall be responsible
for the verification and review thereof. Nothing contained in this Section 15.9
shall be deemed to impair, limit or otherwise affect Mall II Buyer's rights
under this Agreement in respect of the representations and warranties of
Developer set forth in this Agreement and the other provisions hereof binding
upon Developer, and the disclaimers
43
of this Section 15.9 shall not apply to any information so represented or
warranted by Developer. The provisions of this Section 15.9 shall survive the
Closing Date or any termination of this Agreement.
15.10 Knowledge. All representations and warranties made herein by
Developer which are based on Developer's knowledge are made, and are hereby
acknowledged by Mall II Buyer to be made, to the actual knowledge of Xxxxxx
Xxxxxxxxx and Xxxxx Xxxxxxxxxxxx, without independent investigation regarding
the facts contained therein.
15.11 Developer's Obligations to Construct Mall Improvements. So
long as this Agreement is in full force and effect and Mall II Buyer is not in
material default, Developer shall not construct any improvements in the Mall
Space other than the Mall Improvements for use as a retail mall in accordance
with this Agreement.
15.12 Survival of Developer's Warranties, etc.
(a) Unless otherwise specified in connection with a
representation or warranty, all of Developer's representations and warranties
contained in this Article 15 (other than those contained in Sections 15.1(a),
15(b), 15(c) and 15.1(g), which shall survive the Closing Date without
limitation as to time), as remade as of the Closing Date as provided in Section
15.12(c) and subject to any modifications thereof made in any certificate
provided for in said Section 15.12(c), shall survive until one (1) year after
the Closing Date; provided, however, that Developer's liability for any breach
of such warranties, representations and certifications shall not expire as to
any breach or alleged breach thereof if notice of such breach or alleged breach
is given by Mall II Buyer to Developer prior to one (1) year after the Closing
Date and, if such notice is given, legal proceedings are instituted in respect
of such breach or alleged breach within six (6) months after such notice is
given. Developer's obligations to perform the Landlord Build-Out Work and to pay
Leasing Costs shall survive until the Earn-Out Date and shall apply to all
Leases executed prior to the Earn-Out Date, with respect to Landlord Build-Out
Work and Leasing Costs which are to be performed or are incurred before the
Earn-Out Date.
(b) Notwithstanding anything to the contrary set forth in this
Article 15, subject to the last sentence of this Section 15.12(b), (i) Developer
shall have no liability to Mall II Buyer for breach of any warranty and
representation set forth in this Article 15 unless and except to the extent that
the damages due to Mall II Buyer by reason of all such breaches exceed Two
Hundred Fifty Thousand Dollars ($250,000) (the "Basket"), (ii) in no event shall
Developer be liable to Mall II Buyer for consequential or punitive damages in
respect of any such breach and (iii) in no event shall Developer's liability to
Mall II Buyer for all such breaches exceed Two Million Dollars ($2,000,000) (the
"Cap"). Notwithstanding anything to the contrary set forth herein, the
limitations on the Basket and Cap shall not apply to a breach of a
representation or warranty contained in Sections 15.1(a), 15.1(b), 15.1(c) or
15.1(g).
44
(c) All of Developer's representations and warranties set
forth in this Article 15 shall be remade on and as of the Closing Date in
Developer's Representation Certificate (the "Developer's Representation
Certificate") in the form of Exhibit B attached hereto and made a part hereof,
which certificate shall be delivered to Mall II Buyer on the Closing Date.
Notwithstanding the foregoing or anything else set forth in this Agreement, if
any matter or event shall have occurred between the date hereof and the Closing
Date or Developer shall otherwise become aware of any fact which makes any such
warranty or representation untrue in any material respect, Developer shall have
the duty to disclose such fact in Developer's Representation Certificate, and if
Developer does so, Developer shall not be liable to Mall II Buyer following the
Closing Date for the breach of the warranty or representation in question which
results from the occurrence or existence of such fact, but in no event shall
Mall II Buyer be obligated to close hereunder unless the conditions precedent to
Mall II Buyer's obligation to close set forth in this Agreement (including,
without limitation, in Section 15.1(a)) shall have been fulfilled.
(d) Notwithstanding anything to the contrary set forth in this
Article 15 or elsewhere in this Agreement, if prior to the Closing Date, Mall II
Buyer has or obtains knowledge that any of Developer's warranties or
representations set forth in this Article 15 is untrue in any respect, and Mall
II Buyer nevertheless proceeds with the Closing, then the breach by Developer of
the warranties, representations or certifications as to which Mall II Buyer
shall have or obtained such knowledge shall be waived by Mall II Buyer and
Developer shall have no liability to Mall II Buyer or its successors or assigns
in respect thereof.
15.13 Indemnification. Developer shall, at Developer's expense,
indemnify, defend and hold harmless Mall II LLC from and against any loss,
liability, damage, cost, or expense (including Fees and Costs) which Mall II LLC
may suffer, or which may be asserted against Mall II LLC, in whole or in part by
reason of, or in connection with any liabilities, obligations, debts, claims,
causes of action, judgments and damages which may be asserted against, imposed
on or incurred by Mall II LLC after the Closing Date, and which do not result
from an act or omission of Mall II Buyer prior to closing, by reason of any of
the following: (i) any obligation of Mall II LLC for borrowed money which was
incurred prior to the Closing; (ii) any claims made against Mall II LLC by any
party with respect to any period prior to the Closing Date; (iii) all
obligations and payments due from Mall II LLC to trade creditors with respect to
any period prior to the Closing Date; (iv) all obligations with respect to
existing litigation against Mall II LLC, or any litigation in connection with
the actions or omissions of Mall II LLC, instituted against Mall II LLC on or
after the Closing Date to the extent based on any event occurring prior to the
Closing Date; (v) any income, excise or franchise taxes or any other federal,
state or local taxes payable by Mall II LLC in respect of any period prior to
the Closing Date; (vi) any other liabilities, obligations, debts, claims, causes
of action, judgments or damages which may be imposed upon, incurred by or
asserted against Mall II LLC and which are based on any event occurring prior to
the Closing Date; (vii) any fine, penalty or the like that is imposed or
assessed by a governmental authority for the period prior to the Closing Date,
whether or not imposed or assessed
45
after the Closing Date; and (viii) any liabilities relating to any employees of
Developer or Mall II LLC to the extent their employment relates to the period
prior to the Closing Date, and any liabilities under employee benefit plans or
collective bargaining agreements of Developer or Mall II LLC with respect to
such employment prior to the Closing Date. Notwithstanding the foregoing, but
without limiting any indemnification expressly provided for in Section 3.5 of
this Agreement, in no event shall the indemnification provided for in this
Section 15.13 apply to any claim, liability, obligation, debt, cause of action,
judgment or damage asserted against or imposed upon Mall II Buyer or Mall II LLC
under or in respect of any Lease or on account of the Landlord Build-Out, except
to the extent that Developer is obligated to pay any Leasing Costs or undertakes
to construct the Landlord Build-Out pursuant to the terms of this Agreement.
15.14 Tsunami. If it is necessary that Tsunami surrender its
leasehold interest in the Phase I Mall because it is anticipated that its
demised space or a portion thereof will need to be occupied by an anchor tenant
in accordance with the Common Area Plan, the Initial Demising Wall Plan, the
Final Demising Wall Plan agreed to by Developer and Mall II Buyer, or any Lease
executed by Mall II LLC in accordance with the provisions hereof, Developer
shall use commercially reasonable efforts at Developer's sole expense to obtain
the surrender of such leasehold interest. If it is not necessary for Tsunami to
surrender its leasehold interests as aforesaid, or if Tsunami surrenders its
leasehold interest and not all of its space is required for such anchor tenant,
Mall II Buyer and Developer agree that such space (or the aforesaid unused
portion of such space) shall remain part of the Phase I Mall notwithstanding
anything in this Agreement to the contrary. If Tsunami does surrender all or a
portion of its leasehold interest, then the surrendered portion anticipated to
be used for the anchor tenant shall be considered part of the Phase II Mall.
15.15 Miscellaneous Covenants of Developer.
(a) From the date hereof until the Closing, Developer shall
not (a) permit Mall II LLC to enter into, modify or amend any Lease except with
Mall II Buyer's prior written consent, (b) enter into any agreement the effect
of which is to cause Developer to be unable to assign the Membership Interests
to Mall II Buyer, or (c) amend any of the organizational documents of Mall II
LLC except as Developer may be required by a lender to amend the same in order
to obtain the necessary financing.
(b) Subsequent to the Closing, Developer shall prepare timely
and file, or cause to be prepared and timely filed, all federal, state and local
income tax returns for Mall II LLC for the period ending on the Closing Date and
pay all amounts due as shown on said returns, which obligations shall survive
the Closing.
46
ARTICLE 16
REPRESENTATIONS AND WARRANTIES
OF MALL II BUYER; CERTAIN AGREEMENTS
16.1 Representations and Warranties of Mall II Buyer. Mall II Buyer
represents and warrants to Developer as follows:
(a) Schedule "10," Part Two, which sets forth representations
and warranties by Mall II Buyer concerning its organization and ownership,
authorization of this Agreement, and other matters, is incorporated herein by
reference.
(b) Except as set forth in Schedule "6," there are no
approvals, authorizations, consents or other actions by or filings with any
Person which are required to be obtained or completed by Mall II Buyer in
connection with the execution and delivery of this Agreement or any of the
Closing Instruments or in connection with any other action required to be taken
by Mall II Buyer hereunder at or before the Closing.
(c) To Mall II Buyer's actual knowledge, there are no
outstanding judgments, orders, writs, injunctions, or decrees of any Government
Authority, no pending Legal Proceedings or material threats of Legal
Proceedings, against Mall II Buyer which would have a material adverse effect on
Mall II Buyer's performance of its obligations under this Agreement or the
Closing Instruments.
(d) No petition for relief or similar Legal Proceeding has
been filed (and not dismissed within 60 days) pursuant to the United States
Bankruptcy Code with respect to Mall II Buyer.
The representations and warranties of Mall II Buyer in this Section are true,
correct, and complete in all material respects as of the date of this Agreement.
Before the Closing Date, Mall II Buyer shall give Developer updates of Schedules
"6" and "10" so that, with the information and revisions then reflected in such
updates, the representations and warranties in this Section shall be true,
correct and complete as of the Closing Date.
16.2 Liens. Developer shall bond or otherwise discharge of record,
at Developer's expense, any liens filed against the Building in connection with
the Landlord Build-Out or any contractor or subcontractor of Developer (or any
other Persons claiming through or under Developer). Developer and Mall II Buyer
shall cooperate in order to cause each Tenants to bond or otherwise discharge of
record, at such Tenant's expense, any liens filed against the Building in
connection with the Tenant Build-Out by any contractor or subcontractor of such
Tenant (or any other Persons claiming through or under Tenant).
16.3 Retail and Restaurant Leases.
(a) From and after the date hereof and continuing until the
Earn-Out Date, Mall II Buyer and Developer shall be jointly responsible for the
leasing
47
of retail and restaurant space in the Phase II Mall. Developer (prior to the
Closing Date) and Mall II Buyer (from and after the Closing Date until the
Earn-Out Date) shall cause Mall II LLC, as landlord, to enter into Leases for
retail stores and restaurants to be located in the Phase II Mall with tenants
jointly selected by Mall II Buyer and Developer and on terms mutually acceptable
to Mall II Buyer and Developer. Mall II Buyer and Developer shall lease space in
the Phase II Mall, including any retail carts or kiosks located in the Phase II
Mall, to tenants who are retail or restaurant tenants appropriate for and
consistent with, a quality and standard for the Phase II Mall and its aggregate
occupant mix that is not less than the quality and standard of the "Grand Canal
Shoppes at the Venetian" as of the date hereof. In addition, all Leases for
restaurants executed prior to the Earn-Out Date shall be entered into with
tenants operating "specialty 2-star" restaurants or better. The consent of both
of Mall II Buyer and Developer shall be necessary for the execution of any Lease
prior to the Earn-Out Date. Both parties will use commercially reasonable
efforts to include a 15% administrative fee and provisions for reimbursement of
a 3% management fee in all Leases.
(b) From and after the date hereof and continuing until the
Earn-Out Date (and from and after the Earn-Out Date until the Final Date (as
defined in Section 20.3) to the extent the Recalculated Earn-Out (as defined in
Section 20.3) would or might be affected), no Lease amendment that would or
might affect net operating income through the Earn-Out Date or termination
agreement shall be entered into unless approved by both Mall II Buyer and
Developer, no monetary or other material obligation in any Lease that accrues
prior to the Earn-Out Date shall be waived unless such waiver is approved by
both Mall II Buyer and Developer, and no Lease shall be terminated unless such
termination is approved by both Mall II Buyer and Developer. From and after the
date hereof until the Final Date, (i) if Developer requests that Mall II LLC
conduct an audit of a tenant to determine if such tenant, with respect to any
period of time prior to the Earn-Out Date, underpaid "percentage" or "overage"
rent, Mall II Buyer shall cause Mall II LLC to diligently conduct such audit
"in-house" in accordance with procedures reasonably agreed to by Mall II Buyer
and Developer, and shall keep Developer informed of the results of such audit
and (ii) if any tenant exercises its right to conduct an audit of Mall II LLC's
"CAM" charges or other recoverable expenses, Developer and Mall II Buyer shall,
subject to compliance with the applicable Lease provisions, jointly make all
decisions in connection therewith and in connection with any proposed settlement
with such tenant related thereto, and Mall II Buyer shall cause Mall II LLC to
take actions consistent with such decisions.
(c) Prior to the Closing Date, any security deposit or other
payment received from Tenants ("Tenant Payments") shall be held by Mall II LLC
or, if Mall II LLC has not yet been formed, by Developer in a separate interest
bearing account. Promptly after the formation of Mall II LLC, Developer shall
transfer any Tenant Payments so held by Developer to an account of Mall II LLC.
Prior to the Closing, all Tenant Payments held by Developer or by Mall II LLC
pursuant to this Section 16.3 (c) shall be maintained in an interest-bearing
account. At the Closing, the Tenant Payments will remain the possession of Mall
II LLC and there shall be no adjustment made to the Closing Payment or any other
payments due under this Agreement in respect of such Tenant Payments.
48
16.4 Compliance with Gaming Laws by Tenants. Mall II Buyer
acknowledges that Developer and Affiliates of Developer conduct businesses that
are or may be subject to and exist because of privileged licenses issued by
Gaming Authorities. Therefore, not less than thirty (30) days prior to Mall II
LLC entering into any Lease (a "Proposed Lease"), Mall II Buyer and Developer
shall cause the tenant under such Proposed Lease (the "Proposed Tenant"), if
such Proposed Tenant is a corporation, to disclose to Mall II Buyer and
Developer the names of all of its officers and directors. Unless it is a
publicly traded corporation on a national stock exchange, the Proposed Tenant
shall disclose to Mall II Buyer and Developer all direct and indirect ownership
interests in the Proposed Tenant and all lenders or sources of financing. If
requested to do so by Developer, Mall II Buyer shall require a Proposed Tenant
to obtain any license, qualification, clearance or the like which shall be
requested or required of any Proposed Tenant by any Gaming Authority or any
regulatory authority having jurisdiction over Developer or any Affiliate of
Developer. If a Proposed Tenant fails to satisfy such requirement or if
Developer or any Affiliate of Developer is directed not to involve itself in
business with a Proposed Tenant by any such authority, or if Developer shall in
good faith determine that a Proposed Tenant, or any of its officers, directors,
employees, agents, designees or representatives, or a partner, owner, member, or
shareholder, or any lender or financial participant (a) is or might be engaged
in, or is about to be engaged in, any activity or activities, or (b) was or is
involved in any relationship, either of which could or does jeopardize
Developer's business, reputation or such licenses, or those of its Affiliates,
or if any such license is threatened to be, or is, denied, curtailed, suspended
or revoked, then Mall II LLC, at Developer's direction, shall not enter into the
Proposed Lease with the Proposed Tenant. Any Lease entered into in violation of
this Section 16.4 shall be deemed null and void and of no force or effect. All
Leases shall include the provision set forth in Schedule "19" attached hereto
and made a part hereof. To the extent any Lease shall not include the provision
set forth in Schedule "19," such Lease shall be null and void and of no force or
effect. Developer and its successors and assigns shall be a third-party
beneficiaries of the provision described in Schedule "19" (and the applicable
Leases shall so provide) and Developer and its successors and assigns shall have
the right to take all appropriate action to enforce such provision, including
initiating and prosecuting to completion eviction proceedings. The provisions of
this Section 16.4 shall survive until the Closing at which point the inclusion
of gaming provisions in the Leases or Proposed Leases shall be governed by the
Amended REA.
16.5 Compliance with Gaming Laws by Mall II Buyer. Mall II
Buyer acknowledges that Developer and Affiliates of Developer conduct businesses
that are or may be subject to and exist because of privileged licenses issued by
Gaming Authorities. Mall II Buyer has disclosed to Developer the names of all of
its officers and directors on Part Two of Schedule "10." Mall II Buyer has also
disclosed on Schedule "10" all direct and indirect ownership interests in Mall
II Buyer (excluding (i) any holders of publicly traded shares of General Growth
Properties, Inc. or (ii) any limited partners of GGP Limited Partnership that
are Institutional Investors) and all lenders or sources of financing that are
not Institutional Investors. Mall II Buyer shall promptly notify Developer of
any occurrence which might make the information set forth on Schedule "10"
incorrect or incomplete. If requested to do so by Developer, Mall II Buyer
49
shall obtain any license, qualification, clearance or the like which shall be
requested or required of Mall II Buyer by any Gaming Authority or any regulatory
authority having jurisdiction over Developer or any Affiliate of Developer. If
Mall II Buyer fails to satisfy such requirement or if Developer or any Affiliate
of Developer is directed not to involve itself in business with Mall II Buyer by
any such Gaming Authority, or if Developer shall in good faith determine that
Mall II Buyer, or any of its officers, directors, employees, agents, designees
or representatives, or a partner, owner, member, or shareholder, or any lender
or financial participant (a) is or might be engaged in, or is about to be
engaged in, any activity or activities, or (b) was or is involved in any
relationship, either of which could or does jeopardize Developer's business,
reputation or such licenses, or those of its Affiliates, or if any such license
is threatened to be, or is, denied, curtailed, suspended or revoked, then Mall
II Buyer, at Developer's direction, shall immediately (i) terminate any
relationship with the individual or entity which is the source of the problem or
(ii) cease the activity creating the problem. If Mall II Buyer does not comply
with item (i) or (ii) above, then Developer may require Mall II Buyer to
specifically perform such obligation (the parties recognizing that damages or
other remedies would be inadequate under the circumstances). The provisions of
this Section 16.5 shall survive until the Closing at which point Mall II Buyer's
compliance with the Gaming Authorities shall be governed by the Amended REA.
16.6 Remaking of Warranties; Survival. All of Mall II Buyer's
representations and warranties set forth in this Article 16 shall be deemed to
have been remade on and as of the Closing Date, and Mall II Buyer shall deliver
a certificate at Closing recertifying such representations and warranties. Such
representations and warranties, as remade, shall survive the Closing without
limitation as to time. The covenants made by Mall II Buyer in Article 4, Article
5 and this Article 16 shall survive the Closing without limitation as to time.
ARTICLE 17
TRANSACTION EXPENSES; TITLE INSURANCE
17.1 Fees and Costs of Attorneys and Consultants. Except as
otherwise provided herein, each party shall pay the Fees and Costs of its own
attorneys and Consultants in connection with this Agreement and the transactions
contemplated hereunder.
17.2 Title Premiums. Mall II Buyer shall pay the costs for the
issuance of the Title Insurance Commitment and the insurance effected pursuant
thereto.
17.3 Real Property Transfer Taxes. Developer shall pay on or prior
to the Closing Date all State and County real property transfer taxes (if any)
payable in connection with the conveyance of the Membership Interests to Mall II
Buyer.
17.4 Apportionments. Real property taxes, water and sewage charges
and utilities and fuel charges to be paid with respect to the Phase II Mall
shall be apportioned at the Closing, with Developer to be responsible for Mall
II LLC's
50
obligations in regard thereto through the day preceding the Closing Date and
Mall II Buyer to be responsible for Mall II LLC's obligations in regard thereto
for the period including and following the Closing Date.
17.5 Payments Under Amended REA. Mall II Buyer's obligation to cause
Mall II LLC to pay any and all charges apportioned to Mall II LLC under the
terms of the Amended REA will commence as of the Closing Date.
17.6 The provisions of this Article 17 shall survive the Closing.
ARTICLE 18
DAMAGE OR DESTRUCTION; CONDEMNATION
18.1 Major Event. As used herein, "Major Event" means the giving of
official notice by a Government Authority of a condemnation or taking under the
power of eminent domain of any part of the Building or the Phase II Land (a
"Condemnation"), which Condemnation involves all or a substantial portion of the
Phase II Land or the Building so that Developer would be unable to satisfy the
conditions set forth in Article 10.
18.2 Termination after Major Event. Developer shall give notice to
Mall II Buyer of the occurrence of a Major Event, in which event, this Agreement
shall terminate thirty (30) days after the giving of such notice. If this
Agreement is terminated as aforesaid, neither Mall II Buyer nor Developer shall
have any further rights or obligations to the other hereunder, except those that
survive termination.
18.3 Restoration after Casualty or Condemnation. If (a) (after
Developer commences construction) a fire or other casualty occurs to the Mall
Improvements or (b) a Condemnation that is not a Major Event shall occur,
Developer shall proceed, at Developer's expense, to reconstruct or restore the
damaged or taken portions of the Mall Improvements or the Phase II Land and
thereafter will complete restoration and reconstruction as promptly as possible;
and the Closing Date or the Outside Substantial Completion Date and, if the same
has been agreed to, the Opening Date shall be adjourned automatically, taking
into account all relevant facts and circumstances, to allow for such restoration
or reconstruction. There shall be no adjustment made to the Closing Payment or
the Earn-Out Payment in regard of such reconstruction.
18.4 Waiver. This Article constitutes an express waiver by the
parties of any law apportioning risk of loss under contracts for the sale or
purchase of real property.
18.5 Insurance Proceeds. All proceeds of insurance and/or
condemnation payable by reason of a Major Event or other casualty or
condemnation affecting the Building before the Closing shall belong to
Developer.
51
ARTICLE 19
REMOVAL OF TITLE DEFECTS
19.1 Title Defect. "Title Defect" means any Encumbrance recorded
against, or otherwise affecting, the Phase II Mall which is not a Permitted
Encumbrance.
19.2 Notice and Removal of Title Defects. On or before the Closing
Date, Mall II Buyer shall promptly give Developer notice of any Title Defect of
which it becomes aware. If Mall II Buyer gives notice to Developer of any such
Title Defect, Developer may adjourn the Closing for a period or periods not
exceeding forty-five (45) days in the aggregate in order to remove the Title
Defect(s) specified in Mall II Buyer's notice. Upon the expiration of such
period(s) (or on the Closing Date if sooner and if Developer does not so adjourn
the Closing), if Developer is unable (subject to Article 21 hereof) or is not
required to satisfy the conditions in Section 10.1(d) of this Agreement, then
provided that the Title Defect does not prevent the operation by Mall II LLC of
a mall in the Mall Space, Mall II Buyer shall accept such title as Developer is
then able to provide and the Closing Payment shall be reduced in an amount equal
to the amount by which such Title Defect(s) reduce the value of the Phase II
Mall, as such reduction shall be determined by the Developer and Mall II Buyer
after good faith consultations. If Developer and Mall II Buyer are unable to
agree on the amount of the reduction in the Closing Payment, an Independent
Expert shall determine the amount pursuant to Article 9.
19.3 Discharge of Mortgages and Liens. Developer agrees, without
further notice from Mall II Buyer, to pay and discharge at the Closing all
Mortgages against the Phase II Mall, and to remove and discharge of record, by
payment, bonding or otherwise, other liens of record against the Phase II Mall
which may be satisfied by payment of money only and which are not Permitted
Encumbrances. Except as specified in this Section, Developer shall have no
obligation to remove or cure Encumbrances.
19.4 Title Affidavits. At or before the Closing, Developer shall
execute and deliver to the Title Insurer such affidavits as are customarily
given by a seller to induce the Title Insurer to issue the title policy
described in Section 10.1(d) including, without limitation, a non-imputation
endorsement thereto.
19.5 Judgment Searches. If a search of the title discloses
judgments, bankruptcies or other returns against other Persons having names the
same as or similar to those of Developer or Mall II LLC, Developer will
establish to the satisfaction of Mall II Buyer and the Title Insurer that such
judgments, bankruptcies or other returns are not against Developer or Mall II
LLC.
52
ARTICLE 20
CLOSING AND OTHER PAYMENTS
20.1 Upon and subject to the terms and conditions of this Agreement,
the Developer agrees to sell and assign the Membership Interests to Mall II
Buyer and Mall II Buyer agrees to purchase the Membership Interests from the
Developer, to assume the obligations in respect thereof accruing from and after
the Closing Date and to pay to Developer the Closing Payments, the Adjustments
Payments, the Earn-Out Payment, the Recalculated Earn-Out and any other payment
due pursuant to the terms of this Agreement.
20.2 Payments. Developer agrees to construct the Phase II Mall
substantially in accordance with the Initial Plans (before the Final
Construction Drawings and Specs are agreed to by Mall II Buyer and Developer)
and Final Construction Drawings and Specs (once the same are agreed to by Mall
II Buyer and Developer) and the terms of this Agreement, and, in consideration
therefor, Mall II Buyer shall make the following payments to Developer:
(a) Closing Payment. At the Closing, Mall II Buyer shall pay
to Developer by wire transfer of immediately available federal funds to an
account designated by Developer an amount (the "Closing Payment") equal to the
greater of (i) two hundred and fifty million dollars ($250,000,000) and (ii) the
projected net operating income divided by the Cap Rate. As used in this
Agreement, the "Cap Rate" shall mean (A) .06 for every dollar of net operating
income up to thirty-eight million dollars ($38,000,000) and (B) (without
modifying or nullifying clause (A)) .08 for every dollar of net operating income
including and above thirty-eight million dollars ($38,000,000). If, despite good
faith efforts by Developer and Mall II Buyer to arrive at an appropriate amount
of the Closing Payment, there is a disagreement over the amount of the Closing
Payment, the parties shall agree to close despite such disagreement and Mall II
Buyer shall pay to Developer the entire undisputed portion of the Closing
Payment subject to the following sentence. Upon resolution by Mall II Buyer and
Developer (or by the Independent Expert) of the disputed amount, Mall II Buyer
shall also pay to Developer interest at the Interest Rate on the amount
calculated pursuant to this Section 20.2(a), to the extent unpaid, for the
period from the Closing Date to the date on which the Closing Payment is made to
Developer.
(b) Adjustment Payments.
(1) On the Business Day immediately preceding each
of the six (6) month anniversary, the twelve (12) month anniversary, the
eighteen (18) month anniversary and the twenty-four (24) month anniversary of
the Closing Date (each an "Interim Payment Date" and, collectively, the "Interim
Payment Dates"), Mall II Buyer shall pay to Developer by wire transfer of
immediately available federal funds to an account designated by Developer an
amount (each an "Adjustment Payment" and, collectively, the "Adjustment
Payments") equal to the positive difference, if any, between
53
(i) the net operating income divided by the Cap Rate and (ii) (A) the sum of the
Closing Payment and the net aggregate amount of any Adjustment Payments made to
Developer, if any, made on previous Interim Payment Dates minus (B) the amount
of any free rent granted to Tenants under any Leases included in the calculation
of net operating income as of such Interim Payment Date for the period from the
immediately prior Interim Payment Date (or the Closing Date, for the first
Adjustment Payment) up to and including such Interim Payment Date. If, despite
good faith efforts by Developer and Mall II Buyer to arrive at an appropriate
amount of any Adjustment Payment, there is a disagreement over the amount of
such Adjustment Payment from Mall II Buyer to Developer, Mall II Buyer shall pay
to Developer the entire undisputed portion of the Adjustment Payment, if any,
subject to the following sentence. Upon resolution by Mall II Buyer and
Developer (or by the Independent Expert) of the disputed amount, Mall II Buyer
shall also pay to Developer, as part of each Adjustment Payment, interest at the
Interest Rate on the amount calculated pursuant to this Section 20.2(b), to the
extent unpaid, for the period from the Interim Payment Date to the date on which
the applicable Adjustment Payment is made to Developer.
(2) In the event that, on any Interim Payment
Date, the amount set forth in clause (ii) is greater than the amount set forth
clause (i) of Section 20.2(b)(1), Developer shall pay the amount of such
difference to Mall II Buyer by wire transfer of immediately available federal
funds to an account designated by Mall II Buyer. If, despite good faith efforts
by Developer and Mall II Buyer to arrive at an appropriate amount of any
Adjustment Payment from Developer to Mall II Buyer, there is a disagreement over
the amount of such Adjustment Payment, Developer shall pay to Mall II Buyer the
entire undisputed portion of the Adjustment Payment, if any, subject to the
following sentence. Upon resolution by Mall II Buyer and Developer (or by the
Independent Expert) of the disputed amount, Developer shall also pay to Mall II
Buyer, as part of each such payment, interest at the Interest Rate on the amount
calculated pursuant to the preceding sentence, to the extent unpaid, for the
period from the Interim Payment Date to the date on which such payment is made
to Mall II Buyer. Notwithstanding the foregoing, Developer shall have no
obligation to make any payments pursuant to this Section 20.2(b)(2) which would
have the effect of reducing the net aggregate amount received by Developer from
Mall II Buyer pursuant to the Closing Payments and the Adjustment Payments
(excluding amounts received that constitute interest on amounts not paid on the
date due) below two hundred and fifty million dollars ($ 250,000,000).
(c) Earn-Out Payment.
(1) On the date that is thirty (30) months after
the Closing Date (the "Earn-Out Date"), Mall II Buyer shall pay to Developer by
wire transfer of immediately available federal funds to an account designated by
Developer, an amount (with interest as provided below, the "Earn-Out Payment")
equal to the positive difference, if any, between (i) the net operating income
divided by the Cap Rate and (ii) (A) the sum of the Closing Payment and the net
aggregate amount of all Adjustment Payments made to Developer, if any, minus (B)
the amount of any free rent granted to Tenants under any Leases included in the
calculation of net operating income as of the
54
Earn-Out Date for the period from the final Interim Payment Date up to and
including the Earn-Out Date. If, despite good faith efforts by Developer and
Mall II Buyer to arrive at an appropriate amount of the Earn-Out Payment from
Mall II Buyer to Developer, there is a disagreement over the amount of the
Earn-Out Payment, Mall II Buyer shall pay to Developer the entire undisputed
portion of the Earn-Out Payment, if any, that the parties can agree is payable
from Mall II Buyer to Developer, subject to the following sentence. Upon
resolution by Mall II Buyer and Developer (or by the Independent Expert) of the
disputed amount, Mall II Buyer shall also pay to Developer, as part of the
Earn-Out Payment, interest at the Interest Rate on the amount calculated
pursuant to this Section 20.2(c), to the extent unpaid, for the period from the
Earn-Out Date to the date on which the Earn-Out Payment is made to Developer. In
the event that a Market Disruption Event shall occur, then Developer shall have
the right, but not the obligation, to extend the Earn-Out Date up to one day for
each day that such Market Disruption Event shall continue. A "Market Disruption
Event" shall have been deemed to have occurred on the first day of the month
(the "Initial Market Disruption Date") when, in response to a specific event or
series of events (for example a contagious disease outbreak or terrorist event
which results in decreased numbers of travelers), the total number of airline
passengers enplaning and deplaning at McCarran International Airport, Las Vegas,
Nevada, in any given month, as reported by the Las Vegas Convention and Visitors
Authority in either its "MONTHLY EXECUTIVE SUMMARY" or its annual "YEAR-TO-DATE
EXECUTIVE SUMMARY" (or some other verifiable source of such similar statistical
information) ("McCarran Passengers") decreases more than twenty percent (20%) as
compared to the same month in the prior year. Such Market Disruption Event shall
be deemed to continue until the last day of the month in which the number of
McCarran Passengers for such month is equal to or greater than the number of
McCarran Passengers in the same month in the prior year, but in no event shall
the Earn-Out Date be delayed for longer than one (1) year due to such Market
Disruption Event.
(2) In the event that, on the Earn-Out Date, the
amount set forth in clause (ii) is greater than the amount set forth in clause
(i) of Section 20.2(c)(1), Developer shall pay the amount of such difference to
Mall II Buyer by wire transfer of immediately available federal funds to an
account designated by Mall II Buyer. If, despite good faith efforts by Developer
and Mall II Buyer to arrive at an appropriate amount of the Earn-Out Payment
from Developer to Mall II Buyer, there is a disagreement over the amount of the
Earn-Out Payment, Developer shall pay to Mall II Buyer the entire undisputed
portion of the Earn-Out Payment, if any, that the parties can agree is due from
Developer to Mall II Buyer, subject to the following sentence. Upon resolution
by Mall II Buyer and Developer (or by the Independent Expert) of the disputed
amount, Developer shall also pay to Mall II Buyer, as part of each such payment,
interest at the Interest Rate on the amount calculated pursuant to the preceding
sentence, to the extent unpaid, for the period from the Earn-Out Date to the
date on which such payment is made to Mall II Buyer. Notwithstanding the
foregoing, Developer shall have no obligation to make any payments pursuant to
this Section 20.2(c)(2) which would have the effect of reducing the net
aggregate amount received by Developer from Mall II Buyer pursuant to the
Closing Payment, all Adjustment Payments and the Earn-Out Payment (excluding
amounts received that constitute interest on amounts not paid on the date due)
below two hundred and fifty million dollars ($250,000,000).
55
(d) Other. Any other payment required by the terms of this
Agreement.
20.3 Recalculated Earn-Out. On the eighteen-month anniversary of the
Earn-Out Date (the "Final Date"), each of the parties shall identify by notice
to the other any items that should have been appropriately included as operating
income or operating expenses as of the Earn-Out Date had the parties been aware
of such item (by way of example, and without limitation, any adjustment made
pursuant to a Tenant audit) and recalculate the net operating income and the
Earn-Out Payment taking those items into account (the "Recalculated Earn-Out").
On the Final Date, Mall II Buyer shall pay to Developer the positive difference,
if any, between the Recalculated Earn-Out less the Earn-Out Payment actually
made on the Earn-Out Date. If the Recalculated Earn-Out is less the Earn-Out
Payment, Developer shall pay to Mall II Buyer the amount of such difference. If,
despite good faith efforts by Developer and Mall II Buyer to arrive at an
appropriate amount of the Recalculated Earn-Out from Mall II Buyer to Developer
or from Developer to Mall II Buyer, there is a disagreement over the amount of
the Recalculated Earn-Out, Developer shall pay to Mall II Buyer the entire
undisputed portion of the Recalculated Earn-Out, if any, that the parties can
agree is due from Developer to Mall II Buyer, or Mall II Buyer shall pay to
Developer the entire undisputed portion of the Recalculated Earn-Out, if any,
that the parties can agree is due from Mall II Buyer to Developer, subject to
the following sentence. Upon resolution by Mall II Buyer and Developer (or by
the Independent Expert) of the disputed amount, the party determined to owe
money to the other shall pay to the other, as part of each such payment,
interest at the Interest Rate on the amount calculated pursuant to the preceding
sentence, to the extent unpaid, for the period from the Earn-Out Date to the
date on which such payment is made to the other party. Notwithstanding the
foregoing, Developer shall have no obligation to make any payments pursuant to
this Section 20.3 which would have the effect of reducing the net aggregate
amount received by Developer from Mall II Buyer pursuant to the Closing Payment,
all Adjustment Payments, the Earn-Out Payment and the Recalculated Earn-Out
(excluding amounts received that constitute interest on amounts not paid on the
date due) below two hundred and fifty million dollars ($ 250,000,000).
20.4 Independent Expert. Any dispute in the calculation of the
Closing Payment, the Adjustment Payments, the Earn-Out Payment or the
Recalculated Earn-Out shall be resolved by an Independent Expert in accordance
with Article 9 of this Agreement.
20.5 Audits. Developer or its designee shall have the right, from
time to time following the Closing, until 90 days after receipt by Developer of
the Recalculated Earn-Out, at the Developer's expense during business hours and
on reasonable prior notice to Mall II LLC, to examine and audit so much of the
books and records of Mall II Buyer or Mall II LLC as relate to the calculation
of the Closing Payment, any of the Interim Payment, the Earn-Out Payment or the
Recalculated Earn-Out to verify the operating income and operating expenses
reported by Mall II Owner or Mall II LLC (or any successor of Mall II LLC) in
connection with such payments.
56
ARTICLE 21
PRE-CLOSING REMEDIES
21.1 Mall II Buyer's Remedies.
(a) If Developer has failed to achieve Substantial Completion
by the Outside Substantial Completion Date, Mall II Buyer's remedies shall be as
set forth in Section 7.1.
(b) If Substantial Completion has occurred, but any other
condition to Mall II Buyer's obligation to close under this Agreement as set
forth in Section 10.1 has not been satisfied, then Mall II Buyer shall give
notice to Developer setting forth the conditions that have not been satisfied.
Developer shall have a reasonable period of time, not to exceed one hundred
twenty days (and in no event after the Outside Substantial Completion Date) to
satisfy such conditions. If (1) Developer shall fail to satisfy such conditions
within such cure period, (2) the conditions set forth in this Agreement to
Developer's obligation to close have been satisfied and (3) Mall II Buyer is not
otherwise in default of its obligations under this Agreement, then:
(i) Mall II Buyer shall be entitled to bring a Legal
Proceeding for specific performance of Developer's obligations under this
Agreement, and, if specific performance is available as a remedy to Mall II
Buyer, it shall be the sole and exclusive remedy for Developer's default. Mall
II Buyer may recover from Developer (which Developer shall pay upon demand) all
Fees and Costs paid or incurred by Mall II Buyer to secure specific performance
under this Agreement.
(ii) If Mall II Buyer is unable to obtain specific
performance of Developer's obligations under this Agreement, Mall II Buyer shall
be entitled to terminate this Agreement, in which event Developer shall pay to
Mall II Buyer upon demand the Buyer Liquidated Damages Amount as liquidated
damages.
(iii) If Developer has breached this Agreement by
constructing a project on the Phase II Land and in the Leasehold Airspace that
does not include a substantial mall component or by selling either the Phase II
Mall or the Membership Interests to a third party. and Mall II Buyer is unable
to obtain specific performance of Developer's obligations under this Agreement,
Mall II Buyer shall be entitled to terminate this Agreement and, at Mall II
Buyer's election, either (A) require Developer to pay to Mall II Buyer upon
demand the Buyer Liquidated Damages Amount as liquidated damages or (B) bring a
Legal Proceeding against Developer to recover Mall II Buyer's actual damages.
(c) In the event that Mall II Buyer exercises its remedy to
receive Buyer Liquidated Damages under Section 7.1 or Section 21.1(b)(iii) and
Developer shall, subsequent to the exercise of such remedy, achieve Substantial
Completion of the Mall Improvements or a substantial retail component on the
Phase II Land or in the Leasehold Airspace, Mall II Buyer shall have the right
to consummate the
57
purchase of the Membership Interests (if such improvements have been conveyed to
Mall II LLC) or the purchase of such improvements and the fee and leasehold
interests associated therewith (if such improvements have not been conveyed to
Mall II LLC) within thirty (30) days following notice from Developer to Mall II
Buyer that Substantial Completion has occurred on the terms of this Agreement.
If Mall II Buyer shall exercise such right, Mall II Buyer shall return the Buyer
Liquidated Damages Amount to Developer and shall not receive a credit for such
amounts against the purchase price for the Membership Interests. This provision
shall survive the termination of this Agreement.
21.2 Developer's Remedies. If all conditions to Mall II Buyer's
obligations to close under this Agreement are satisfied and Mall II Buyer shall
fail to close title hereunder and deliver the Closing Payment and the Closing
Instruments on the Closing Date, Developer may exercise any of the following
remedies:
(a) Developer shall be entitled to bring a Legal Proceeding
for specific performance of Mall II Buyer's obligations under this Agreement.
Developer may recover from Mall II Buyer (which Mall II Buyer shall pay upon
demand) all Fees and Costs paid or incurred by Developer to secure specific
performance under this Agreement; or
(b) As Mall II Buyer and Developer agree that it would be
impracticable and extremely difficult to ascertain the actual damages to
Developer as a result of the failure of Mall II Buyer to deliver the Closing
Payment and the Closing Instruments on the Closing Date and that a reasonable
estimate of the damages which Developer would incur as a result of such failure
is the amount of one hundred million dollars ($100,000,000) (the "Developer
Liquidated Damages Amount"), Developer may terminate this Agreement, in which
event upon Developer's demand, Mall II Buyer shall pay to Developer the
Developer Liquidated Damages Amount as liquidated damages for Mall II Buyer's
default; or
(c) As further provided in the Amended REA, Developer may
terminate this agreement and, within sixty (60) days after termination of this
Agreement, elect to purchase the limited liability company membership interests
of Mall I LLC owned by Mall I Buyer for a purchase price (the "Mall I Call
Price") equal to (i) the lesser of (y) the purchase price paid for the limited
liability company membership interests in Mall I LLC by Mall I Buyer pursuant to
the Phase I Mall Sale Agreement and (z) the fair market value of the limited
liability company membership interests in Mall I LLC as of the date that
Developer has achieved Substantial Completion less (ii) the Developer Liquidated
Damages Amount; or
(d) If Developer exercises the remedy set forth in Section
21.2(c) above and if the Mall I Call Price is less than the then-outstanding
indebtedness secured by the Phase I Mall or the interest in Mall I LLC,
Developer may purchase the limited liability company interests in Grand Canal
Shops II LLC for the amount of such indebtedness (whether by paying or assuming
the same) and bring a Legal Proceeding
58
against Mall II Buyer for the difference between the amount so paid or assumed
(including any costs incurred in connection therewith) and the Mall I Call
Price.
21.3 Default under Phase I Mall Sale Agreement. In the event that
the transaction described in the Phase I Mall Sale Agreement is not consummated
as contemplated by such agreement, this Agreement shall automatically terminate.
If the transaction set forth in the Phase I Mall Sale Agreement is not
consummated due to a default by either Grand Canal Shops Mall MM Subsidiary,
Inc. or Grand Canal Shops Mall Subsidiary, LLC under the Phase I Mall Sale
Agreement, upon Mall II Buyer's demand, Developer shall pay to Mall II Buyer the
Mall II Buyer Liquidated Damages Amount as liquidated damages for the
termination of this Agreement. If the transaction set forth in the Phase I Mall
Sale Agreement is not consummated due to a default by Mall I Buyer under the
Phase I Mall Sale Agreement, upon Developer's demand, Mall II Buyer shall pay to
Developer the Developer Liquidated Damages Amount as liquidated damages for the
termination of this Agreement.
ARTICLE 22
POST-CLOSING REMEDIES
After the Closing Date, except for (and excluding) those breaches of
obligations or other matters for which this Agreement provides specific and
exclusive remedies to a particular party (including, without limitation, Section
21.2(c)), each party retains, and may pursue, all rights available at law or in
equity by reason of the other party's failure to keep or perform such other
party's agreements or obligations under this Agreement pertaining to the period
after the Closing Date. The provisions of this Article 22 shall survive the
Closing.
ARTICLE 23
NOTICES
All notices, consents or other communications under this Agreement must be in
writing and addressed to each party at its respective Notice Address set forth
on Schedule "8" attached hereto and made a part hereof (or at any other address
which the respective parties may designate by notice given to the other party
from time to time). Any notice required by this Agreement to be given or made
within a specified period of time, on or before a date certain, shall be deemed
given or made if sent by hand, by fax with confirmed answerback received, or by
registered or certified mail (return receipt requested and postage and registry
fees prepaid). Delivery "by hand" shall include delivery by commercial express
or courier service. A notice sent by registered or certified mail shall be
deemed given on the date of receipt (or attempted delivery if refused) indicated
on the return receipt. All other notices shall be deemed given when actually
received. A notice may be given by a party or by its legal counsel.
59
ARTICLE 24
MISCELLANEOUS
24.1 Further Assurances. Each of the parties shall take such actions
and sign and deliver such other instruments and documents as may be reasonable,
necessary or appropriate to effectuate the transactions contemplated under this
Agreement; provided, however, that the taking of such acts or the execution of
such documents will not result in material cost or liability to the respective
party which is not otherwise required under this Agreement. Without limiting the
foregoing, Developer shall, upon the request of Mall II Buyer from time to time,
provide signed representation letters with respect to revenues and expenses of
Mall II LLC for the period prior to Closing to enable Mall II Buyer's
accountants to render an opinion on Mall II Buyer's or any of its Affiliates'
financial statements, provided that the same shall be at no third party (out of
pocket) cost to Developer and Mall II Buyer shall reimburse Developer for all
reasonable cost and expenses incurred by Developer within fifteen (15) days
written notice of same.
24.2 Governing Law. This Agreement shall be governed and construed
in accordance with the laws of the State (without regard to principles of
conflicts of law).
24.3 Amendment. This Agreement shall not be modified, waived, or
amended except by written agreement executed by all the parties.
24.4 Integration. This Agreement, together with the Schedules and
Exhibits hereto, and any other binder of documents, agreements or instruments
which is specifically stated to form a part of this Agreement or to relate
thereto, constitute(s) the entire agreement between the parties with respect to
the subject matter hereof and supersedes all other prior agreements and
understandings of the parties relating thereto.
24.5 No Waiver. Except as expressly provided in this Agreement, no
delay on the part of any party hereto in exercising any right, power or
privilege hereunder shall operate as a waiver thereof or as a waiver of any
other right, power or privilege hereunder, nor shall any single or partial
exercise of any right, power or privilege hereunder preclude any other or
further exercise hereunder. Except as otherwise provided in this Agreement, the
rights and remedies of each party under this Agreement are cumulative and are
not exclusive of any rights or remedies which the party may otherwise have at
law or in equity.
24.6 Counterparts. This Agreement may be executed (a) in
counterparts, a complete set of which together shall constitute an original and
(b) in duplicates, each of which shall constitute an original. Copies of this
Agreement showing the signatures of the respective parties, whether produced by
photographic, facsimile, digital, computer, or other reproduction, may be used
for all purposes as originals.
60
24.7 Successors and Assigns. This Agreement (and all terms thereof,
whether so expressed or not), shall be binding upon the respective permitted
successors, assigns and legal representatives of the parties and shall inure to
the benefit of and be enforceable by the parties and their respective permitted
successors, assigns and legal representatives.
24.8 Exhibits and Schedules. The Exhibits and Schedules attached
hereto or subsequently incorporated herein are (and shall be deemed) parts of
this Agreement. The headings of this Agreement are for purposes of reference
only and shall not limit or otherwise affect the meaning hereof.
24.9 Assignment Restrictions. Subject to the other provisions of
this Section 24.9, neither Mall II Buyer nor Developer may assign this
Agreement, or any of its rights or obligations herein or hereunder, without the
prior written consent of the other, except an assignment as collateral security
to secure a loan or an assignment made in connection with a foreclosure or
deed-in-lieu of foreclosure of such loan (which are hereby expressly permitted
hereunder). Any attempted assignments in violation of this Section shall be null
and void. Notwithstanding the foregoing, Mall II Buyer shall have the right to
assign this Agreement or its rights hereunder (without the consent of
Developer), in whole or in part, to any Affiliate of Mall II Buyer (i) provided
that such Affiliate is not a Competitor of Developer and (ii) such assignment
would not, in the good faith judgment of Developer, jeopardize any of
Developer's or Developer's Affiliates Gaming Licenses. Any attempted assignments
in violation of this Section shall be null and void. Mall II Buyer shall not be
released from any of its obligations pursuant to this Agreement by virtue of
such assignment.
24.10 Authorization. The signature of any one of a party's
Authorized Representatives, acting alone, shall constitute the duly authorized,
valid and binding act of the party for whom the respective person is the
Authorized Representative. A party may change (or add) Authorized
Representative(s) at any time by notice to the other party; and each party shall
be entitled to rely upon the written certificate or consent of any person
designated by the other party as an Authorized Representative.
24.11 Jurisdiction. Each party irrevocably submits to the
jurisdiction of the courts of (and service of process in) the State and agrees
that any action or proceeding arising out of or relating to this Agreement may
be brought and/or defended in such courts.
24.12 Severability. If any term, covenant, condition or provision of
this Agreement is determined by a final judgment to be invalid or unenforceable,
the remaining terms, covenants, conditions and provisions of this Agreement
shall not be affected thereby; and each other term, covenant, condition and
provision of this Agreement shall be valid and enforceable to the fullest extent
permitted by law.
61
24.13 No Third Persons. Nothing in this Agreement, express or
implied, is intended: (a) to confer on any Person, other than the parties
hereto, any rights, obligations, liabilities, or remedies; (b) to constitute
Mall II Buyer as a partner or co-venturer of Developer; or (c) to waive any
claim or right of any party hereto against any Person who is not a party hereto.
24.14 Construction. This Agreement shall be construed without regard
to any presumption requiring construction against the party drafting this
Agreement.
24.15 Brokers. Developer and Mall II Buyer each represent and
warrant to the other that such party has not had any conversations or dealings
with any broker, finder, or similar party in connection with the transactions
contemplated hereby other than Xxxxxxx Xxxxx. Each party shall indemnify the
other from and against any and all claims, liabilities, losses, damages, costs,
or expenses (including Fees and Costs) arising out of a breach of the foregoing
representation by such party. This Section shall survive the Closing or
termination of this Agreement.
24.16 Attorneys' Fees. In event of any Legal Proceeding between or
among Mall II Buyer and Developer concerning this Agreement, the substantially
prevailing party shall be entitled to reimbursement from the other party for the
Fees and Costs of such proceeding incurred by the prevailing party.
24.17 Rule Against Perpetuities. If this Agreement or any covenants
or provisions herein would otherwise be unlawful, void or voidable for violation
of the Rule against Perpetuities, then the same shall continue until the earlier
of (a) January 1, 2030 and (b) twenty-one (21) years after the death of the
survivor of the descendants of the former President of the United States, Xxxxxx
X.X. Xxxx, living on the date of this Agreement.
24.18 Recordation. The parties agree that this Agreement shall not
be recorded.
24.19 Confidentiality.
(a) Each of the Parties hereto agrees that, except as required
by law (including securities laws, rules and regulations), each will treat as
confidential the terms of this Agreement and the transaction contemplated herein
and that prior to Closing neither will issue a press release, advertisement or
other public communication with respect to this Agreement or relating to the
transaction contemplated herein without the prior approval of the other party.
In addition, Mall II Buyer agrees that it will treat as confidential all
non-public information relating to the Venetian Casino Resort and the Palazzo
Casino Resort and all components thereof furnished to Mall II Buyer by or on
behalf of Developer and that it will not disclose any such information to other
persons or entities except for its attorneys, accountants and consultants, if
any, its lenders, the Title Insurer, its insurance companies and insurance
brokers, its partners or investors, if any, or as may be compelled or required
by law (including securities laws, rules and regulations).
62
If this Agreement is terminated or the Closing does not otherwise occur, Mall II
Buyer shall return to Developer all materials with respect to the Venetian
Casino Resort and the Palazzo Casino Resort and all components thereof furnished
to it by or at the behest of Developer and shall destroy all copies thereof and
notes relating thereto and certify to the Developer in writing that it has done
so. The preceding provisions of this Section 24.19 shall survive any termination
of this Agreement. On the Closing Date, the parties shall either issue a joint
press release reasonably satisfactory to each or, if each issues its own press
release, each such release must be reasonably satisfactory to the other.
(b) Each of the parties hereto agrees that, except as required
by law (including securities laws, rules and regulations), it will treat as
confidential and not disclose the terms of this Agreement, including, without
limitation, the methods of calculating net operating income to any Tenants or
potential Tenants.
24.20 Leasehold Space. At the option of the Developer, the Leasehold
Space may be conveyed to Mall II Buyer as a fee interest rather than a leasehold
interest, in which event the closing deliveries of Developer will be modified
accordingly. All references herein to such leasehold interest shall be deemed
revised, as appropriate, to reflect such transfer of a fee interest.
[Signatures begin on the following page.]
IN WITNESS WHEREOF, Developer and Mall II Buyer have executed this
Agreement as of the date first above written.
LIDO CASINO RESORT, LLC
By: Lido Casino Resort Holding Company, LLC
By: Lido Intermediate Holding Company, LLC
By: Venetian Casino Resort, LLC
By: Las Vegas Sands, Inc.
By:_____________________________________
Name:
Title:
[Signatures continue on the following page.]
GGP LIMITED PARTNERSHIP
By: General Growth Properties, Inc.
By:_____________________________________
Name:
Title:
Schedules and Exhibits
Schedule "1" - Phase II Land
Schedule "2" - Leasehold Airspace
Schedule "3" - Phase IA Airspace
Schedule "4" - Continuing Service Contracts
Schedule "5" - Permitted Encumbrances
Schedule "6" - Consents and Exceptions to Representations of the Parties
Schedule "7" - Miscellaneous Closing Deliveries
Schedule "8" - Authorized Representatives; Notice Addresses
Schedule "9" - Construction Safety & Health Manual
Schedule "10" - Organizational Representations of Developer and Mall II Buyer
Schedule "11" - Definition of Substantial Completion
Schedule "12" - REA
Schedule "13" - Mall II Buyer Legal Rates
Schedule "14" - Tenant Handbook
Schedule "15" - Cost Sharing Allocations
Schedule "16" - Master Lease Agreement
Schedule "17" - Intentionally Omitted
Schedule "18" - Leases
Schedule "19" - Gaming Provisions
Schedule "20" - Work Continuation Agreement
Exhibit A - Standards Document attaching Leasing Plans and Character
Sketches
Exhibit B - Developer's Representation Certificate
SCHEDULE "1"
PHASE II LAND
Schedule "1" - Page 1
SCHEDULE "2"
LEASEHOLD AIRSPACE
Schedule "2" - Page 1
SCHEDULE "3"
PHASE IA AIRSPACE
Schedule "3" - Page 1
SCHEDULE "4"
CONTINUING SERVICE CONTRACTS
1. An Energy Services Agreement with Sempra that conforms with the
requirements set forth in the REA.
2. All public utility supply and distribution services, water, sewer and
electricity provided by such entities as Nevada Power, Las Vegas Valley Water
District and Xxxxx County Water Reclamation District, pursuant to statutory and
regulatory standards and pricing.
Schedule "4" - Page 1
SCHEDULE "5"
PERMITTED ENCUMBRANCES
1. Liens for Impositions which are not due and payable as of the
Closing Date or which are apportioned in accordance with Section 17.4.
2. The state of facts shown on the survey to be delivered prior to
Closing Date described in Section 14.6 and any state of facts a physical
inspection of the Property would show (provided the same do not disclose any
matter materially adverse to the property which is not disclosed in the
Standards Document and which has not otherwise been disclosed in writing to Mall
II Buyer prior to the date hereof).
3. Zoning, subdivision, environmental, building and all other Legal
Requirements presently existing, or enacted prior to the Closing Date,
applicable to the ownership, use or development of or the right to maintain or
operate the Phase II Mall or have space therein used and occupied by tenants.
4. Leases reasonably satisfactory to Mall II Buyer reflecting the
expansions contemplated by Section 30.1 of each of the "Gondola Lease" and the
"VCR Showroom Lease" (as such terms are defined in the Mall I Agreement).
5. The REA and, when executed, the Amended REA.
6. Liens or Encumbrances arising as a result of the act or omission
of Mall II Buyer, its Consultants, agents, employees or Affiliates or acts of
Tenants and their contractors or subcontractors.
7. Rights of Tenants, as tenants only, under the Leases.
8. Sewer, water, electric, plumbing, heating, gas, telephone and
other utility easements and easements for ingress and egress for construction,
installation, operation and maintenance of municipal service facilities and
utilities, and all other covenants and other encumbrances of record that do not
interfere in any material respect with the use or operation of the Phase II
Mall.
9. Promptly after the signing of this Agreement, Mall II Buyer and
Developer shall review the title report received in respect of the Mall Space
and shall reasonably agree upon additional items that should be added to this
Schedule "5" as Permitted Encumbrances.
Schedule "5" - Page 1
SCHEDULE "6"
CONSENTS AND EXCEPTIONS (IF ANY) TO REPRESENTATIONS OF THE PARTIES
1. Exceptions (If Any) to Developer's Representations: Developer advises
that:
NONE
2. Exceptions (If Any) to Mall II Buyer's Representations: Mall II Buyer
advises Developer that:
NONE
Schedule "6" - Page 1
SCHEDULE "7"
MISCELLANEOUS CLOSING DELIVERIES
FROM DEVELOPER TO MALL II BUYER:
1. Organizational Documentation of Developer:
(a) certified copy of certificate of formation;
(b) certificate(s) of good standing dated as of a date within
14 days of the Closing Date, evidencing that Developer is in good standing in
the State;
(c) certificate of resolutions of the members of Developer
authorizing this Agreement and the transactions contemplated thereby on behalf
of Developer and Mall II LLC, if such is required; and
(d) certificate of incumbency of Persons executing the
Agreement on behalf of Developer.
2. Organizational Documentation of Mall II LLC:
(a) certified copy of certificate of formation;
(b) certificate(s) of good standing dated as of a date within
14 days of the Closing Date, evidencing that Mall II LLC is in good standing in
the State; and
(c) certified copy of Operating Agreement.
FROM MALL II BUYER TO DEVELOPER:
1. Organization Documentation:
(a) certified copy of certificate of limited partnership;
(b) certificate of good standing dated as of a date within 14
days of the Closing Date evidencing that Mall II Buyer is in good standing in
the State;
(c) certificate of resolutions of the partners of Mall II
Buyer authorizing this Agreement and the transactions contemplated thereby; and
(d) certificate of incumbency of Persons executing the
Agreement on behalf of Mall II Buyer.
Schedule "7" - Page 1
SCHEDULE "8"
AUTHORIZED REPRESENTATIVES; NOTICE ADDRESSES
FOR DEVELOPER:
(a) Authorized Representatives:
Xxxxxxx X. Xxxxxxx, Chairman of the Board and Treasurer
Xxxxxxx X. Xxxxxxx, President
Xxxxxxx X. Xxxxx, Executive Vice President
Xxxxxx X. Xxxxxxxxx, Senior Vice President
Xxxxx X. Xxxxxxxxxxxx, Secretary
(b) Notice Address:
Lido Casino Resort, LLC
0000 Xxx Xxxxx Xxxxxxxxx Xxxxx
Xxxx 0X
Xxx Xxxxx, XX 00000
Tel: (000) 000-0000
Fax (000) 000-0000
Attention: Xxxx Xxxxx
with a copy to:
Xxxx, Weiss, Rifkind, Xxxxxxx & Xxxxxxxx LLP
0000 Xxxxxx xx xxx Xxxxxxxx
Xxx Xxxx, Xxx Xxxx 00000
Tel.: (000) 000-0000
Fax: (000) 000-0000
Attention: Xxxxxx X. Xxxxxxx, Esq.
FOR MALL II BUYER:
Schedule "8" - Page 1
(a) Authorized Representatives:
Xxxx Xxxxx
Xxx Xxxxx
Xxx Xxxxxxx
(b) Notice Address:
GGP Limited Partnership
000 Xxxxx Xxxxxx Xxxxx
Xxxxxxx, Xxxxxxxx 00000
Tel.: (000) 000-0000
Fax: (000) 000-0000
Attention: Xxxx Xxxxx
with a copy to:
Xxxx, Xxxxxx & Xxxxxxxxx, LLP
Xxx Xxxxx XxXxxxx Xx., Xxxxx 0000
Xxxxxxx, Xxxxxxxx 00000
Tel.: (000) 000-0000
Fax: (000) 000-0000
Attention: Xxxxxxxx X. Xxxxxxxxx, Esq.
Schedule "8" - Page 2
SCHEDULE "9"
CONSTRUCTION SAFETY & HEALTH MANUAL
Schedule "9" - Page 1
SCHEDULE "10"
ORGANIZATIONAL REPRESENTATIONS OF DEVELOPER AND MALL II BUYER
PART ONE - DEVELOPER:
1. Developer is a limited liability company duly organized, validly
existing, and in good standing under the laws of the State and duly qualified to
transact business in the State.
2. Developer has all necessary power and lawful authority to own and
operate its assets and properties and to carry on its business (including all
transactions contemplated under this Agreement and the Closing Instruments).
3. Developer has delivered to Mall II Buyer a true, correct, and
complete copy of the certificate of formation by which Developer was formed,
together with all amendments thereof.
4. The execution and delivery by Developer of this Agreement and the
Closing Instruments, and the consummation by Developer of the transactions
contemplated thereby, have been duly authorized by all necessary action of
Developer and duly approved by all members and managers of Developer whose
approval is required.
5. The execution and delivery of this Agreement and the Closing
Instruments by Developer, and the consummation of the transactions contemplated
hereby, will not: (i) violate any provision of Developer's certificate of
organization or the limited liability operating agreement of Developer; or (ii)
to the actual knowledge of Developer and except for the failure to secure any
consents specified in Schedule "6," result in the acceleration of any material
indebtedness of Developer.
PART TWO - MALL II BUYER:
1. Mall II Buyer is a limited partnership duly organized and validly
existing under the laws of the State of Delaware.
2. Mall II Buyer has all necessary power and lawful authority to own
and operate its assets and properties and to carry on its business (including
all transactions contemplated under this Agreement and the Closing Instruments).
3. Mall II Buyer has delivered to Developer true and complete copies
of the certificate of limited partnership of Mall II Buyer by which Mall II
Buyer was formed, together with all amendments thereof.
4. The execution and delivery of this Agreement and the Closing
Instruments by Mall II Buyer, and the consummation by Mall II Buyer of the
transactions contemplated thereby, have been duly authorized by all necessary
action of Mall II Buyer and duly approved by the directors of Mall II Buyer.
Schedule "10" - Page 1
5. The execution and delivery of this Agreement and the Closing
Instruments by Mall II Buyer, and the consummation of the transactions
contemplated thereby, will not: (a) violate any provision of Mall II Buyer's
operating agreement; (b) require the consent of any other Person except as set
forth in Schedule "6"; (c) violate any judgment, order, injunction, award or
decree of any Government Authority against or binding upon Mall II Buyer or upon
the property or business of Mall II Buyer; (d) result in the acceleration of any
material indebtedness of Mall II Buyer.
6. The officers and directors of Mall II Buyer are as follows:
Mall II Buyer has no officers or directors.
7. The following are all holders of direct and indirect ownership
interests in Mall II Buyer, other than those public shareholders of General
Growth Properties, Inc. or those limited partners of GGP Limited Partnership:
SEE ATTACHED
8. The following are all lenders or sources of financing to Mall II
Buyer:
None, other than institutional investors, as of execution of the
Agreement.
PART THREE - MALL II LLC:
1. Mall II LLC is a limited liability company duly organized and
validly existing under the laws of a state as determined by Mall II Buyer and
Developer.
2. Mall II LLC has all necessary power and lawful authority to own
and operate its assets and properties and to carry on its business (including
all transactions contemplated under this Agreement and the Closing Instruments).
3. Developer has delivered to Mall II Buyer a true, correct, and
complete copies of the certificate of formation of Mall II LLC and the Limited
Liability Company Agreement of Mall II LLC, together with all amendments
thereof.
4. Prior to the Assignment, Mall II LLC was wholly owned by
Developer. Developer has consented to and approved consummation by Mall II LLC
of the transactions contemplated by this Agreement.
5. The consummation by Mall II LLC of the transactions contemplated
by this Agreement will not: (a) violate any provision of Mall II LLC's Limited
Liability Company Agreement; (b) require the consent of any other Person except
as set forth in Schedule "6," (c) violate any judgment, order, injunction, award
or decree of any Government Authority against or binding upon Mall II LLC or
upon the property or business of Mall II LLC; (d) result in the acceleration of
any material indebtedness of Mall II LLC.
Schedule "10" - Page 2
SCHEDULE "11"
DEFINITIONS OF SUBSTANTIAL COMPLETION AND PUNCH LIST ITEMS
1. "Substantial Completion" means and shall be deemed to have
occurred when:
(a) All Mall Improvement construction work is complete in
accordance with the Final Construction Drawings and Specs, as they may be
revised pursuant to Section 3.3 of the Agreement, and the requirements of
Section 3.1 excepting Punch List Items (defined below) and utilities except to
the extent described below;
(b) All services bringing utilities to the Phase II Mall that
are required to be provided by Developer are installed to the point of
connection with the Tenant Space (in each case as specified in the Final
Demising Wall Plan) but not activated, tested or operating, and temporary
electric service and water sufficient for construction of the Build-Out is
available to the Mall Space but Developer shall not be obligated to bring the
same to each Tenant Space; and installations relating to telephone and
telecommunications required to be provided by Developer are installed;
(c) Developer's Architect has certified that, in Developer's
Architect's opinion, all conditions to Substantial Completion have been met
except for their certifications and/or confirmations pursuant to this paragraph;
(d) Mall II Buyer has received a copy of the certification
(stating that Mall II Buyer may rely thereupon) from Developer's Architect to
Developer that, to the Developer's Architects' professional knowledge,
information and belief, and to the level of observation provided in the
Developer's Architects' agreement with Developer, the Mall Improvement
construction work exclusively performed by Developer, but excluding any Tenant
Spaces or other items relating to the Build-Out, complies with all applicable
building codes;
(e) Developer has delivered to Mall II Buyer a record of all
filings with the buildings department of Xxxxx County with respect to the Mall
Improvements through the date of Substantial Completion, including reports and
results of all controlled inspections for the Phase II Mall;
(f) Developer has delivered to Mall II Buyer copies of the
Required Mall Improvement Permits;
(g) All Demising Walls have been constructed as provided in
the Final Demising Wall Plan; and
(h) Developer shall have delivered to Mall II Buyer a final
certificate of occupancy (or temporary certificate subject to the satisfaction
of non-material conditions, provided that full occupancy is permitted thereunder
and a permanent certificate of occupancy is obtained as promptly as possible
thereafter) for the
Schedule "11" - Page 1
Mall Improvements exclusive of the Tenant Spaces. Mall II Buyer and Developer
acknowledge that the certificate of occupancy, permanent or temporary, covering
the Tenant Spaces shall be the responsibility of Mall II Buyer to obtain.
2. For purposes of this Agreement, "Punch List Items" means minor
touch-ups, corrections, and repairs, and completion of other minor work, none of
which is necessary for Mall II Buyer to operate the Phase II Mall.
Schedule "11" - Page 2
SCHEDULE "12"
REA
Schedule "12" - Page 1
SCHEDULE "13"
MALL II BUYER LEGAL RATES
Mall II Buyer will provide legal services to support joint leasing
efforts at an attorney rate of $325 per hour through 12/31/2005 and $350 per
hour thereafter. Paralegal time will be billed at a significantly lower rate.
Schedule "13" - Page 1
SCHEDULE "14"
TENANT HANDBOOK
Schedule "14" - Page 1
SCHEDULE "15"
COST SHARING ALLOCATIONS
Section references on this Schedule "15" are to
those corresponding sections of the REA, unless otherwise specified.
MALL I OWNER'S AND MALL II OWNER'S SHARE OF HOTEL/CASINO/MALL/SECC COMMON
AREA CHARGES*
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
Maintenance of the $185,000 per Accounting Same as Mall I Owner's Share.
Base Building, Period,** subject to CPI
Building Core and Adjustment.***
Shell, H/C-Mall
Common Areas and
other common
structures and
equipment)
Pest Control and Fire The portion of all actual out- Same as Mall I Owner's Share.
Extinguishers of-pocket costs related to pest
control and fire extinguisher
service that is related or
allocable to the Phase I Mall, as
shown on bills received by the H/C
I Owner from the entities
providing such pest control and
fire extinguisher services.
Parking Garage $30,000 per Accounting Same as Mall I Owner's Share.
Cleaning Period, subject to CPI
Adjustment.
Parking Garage $85,000 per Accounting Same as Mall I Owner's Share.
Security Period, subject to CPI
Adjustment.
Mall Valet Parking $125,000 per Accounting Same as Mall I Owner's Share.
Charge Period, subject to CPI
Adjustment.
Off-Site Employee $760,000 per Accounting Same as Mall I Owner's Share.
Parking Period, subject to CPI
Adjustment and further subject
Schedule "15" - Page 1
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
to equitable adjustments (as
determined by the Independent
Expert if Mall I Owner and
H/C I Owner cannot agree) if:
(i) there are any rent increases
under the existing lease for the
off-site employee parking lot,
(ii) the existing lease for the
off-site employee parking lot is
terminated and H/C I Owner enters
into a new lease for a new
off-site employee parking lot,
and/or (iii) the existing lease
for the off-site employee parking
lot is terminated and H/C I Owner
constructs a new off-site
employee parking facility on land
it or an Affiliate or a
third-party owns. Any such
equitable adjustment pursuant to
clause (iii) of the preceding
sentence shall be based on Mall I
Owner's equitable share, based on
the respective off-site employee
parking needs of each Owner, of
the fair market rent for the
applicable land (unless leased
from a third party and so already
addressed by clause (ii) of the
preceding sentence) and
constructed facility.
Insurance Carried by Mall I Owner's share of the Same as Mall I Owner's Share.
H/C I Owner Pursuant applicable insurance premiums
to the Provisions of shall be determined by the
Article X applicable insurance carriers,
pursuant to, and in accordance
with the procedures described
in, Section 1(c) of Article VI.
HVAC Plant and For each Accounting Period, Same as Mall I Owner's Share,
HVAC Facilities -- the following annualized subject to adjustment by the
Operating Costs monthly charges itemized on ratio of (a) Gross Square
Schedule "15" - Page 2
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
(other than the costs the December 10, 2003 Footage of the Mall II Property
of water, electricity Sempra Energy Solutions (including master leased casino
and natural gas)**** invoice addressed to Grand level retail space and the
Canal Shops Mall, LLC and Walgreen's Air Rights Parcel)
attached hereto as Appendix I (b) Gross Square Footage of
to this Schedule II, subject to the Mall I Property.
CPI Adjustment: Procurement
Charge; Central Plant; Other
Facilities; Central Plant Real
Estate Taxes; and Other
Facilities Real Estate Taxes.
HVAC Plant - Water, $1,500,000 for 2004, adjusted Same as Mall I Owner's Share,
Electricity and annually thereafter as follows: subject to adjustment by the
Natural Gas For every one percent (1%) ratio of (a) Gross Square
Costs**** increase in the amounts Footage of the Mall II Property
charged by the applicable (including master leased casino
electricity providers and level retail space and the
transporters from the first day Walgreen's Air Rights Parcel)
of the prior Accounting Period (b) Gross Square Footage of
to the first day of the the Mall I Property.
applicable Accounting Period
(assuming no change in the
amount of electricity provided
and transported), there shall be
an eight-tenths of one percent
(.8%) increase in the amount
owed by Mall I Owner. For
every one percent (1%)
increase in the amounts
charged by the applicable
natural gas providers and
transporters from the first day
of the prior Accounting Period
to the first day of the
applicable Accounting Period
(assuming no change in the
amount of natural gas provided
and transported), there shall be
an eighteen one-hundredths of
one percent (.18%) increase in
the amount owed by Mall I
Owner. For every one percent
(1%) increase in the amounts
charged by the applicable
Schedule "15" - Page 3
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
water providers and
transporters from the first day
of the prior Accounting Period
to the first day of the
applicable Accounting Period
(assuming no change in the
amount of water provided and
transported), there shall be a
two one-hundredths of one
percent (.02%) increase in the
amount owed by Mall I
Owner.
HVAC Plant and For each Accounting Period, Same as Mall I Owner's Share,
HVAC Facilities -- the sum of (x) $1,645,000 plus subject to adjustment by the
Amortization of (y) the amount of payments to ratio of (a) Gross Square
Initial HVAC Plant be made by Mall I Owner Footage of the Mall II Property
and HVAC Facilities pursuant to paragraph 1(g) of (including master leased casino
Construction Costs Schedule 4.2 of its ESA level retail space and the
and Other Capital (without giving effect to this Walgreen's Air Rights Parcel)
Expenditures**** Schedule II or the Agreement); (b) Gross Square Footage of
provided, however, that if, in the Mall I Property.
any Accounting Period, the
applicable major repairs,
replacements and capital
investments (excluding those
relating to the Other Facilities
(as defined in Mall I Owner's
ESA)) exceed $5 million, and
either Mall I Owner or H/C I
Owner believes that Mall I
Owner's "Proportionate Share"
(as defined in Mall I Owner's
ESA) is not, taking into
account all relevant factors,
Mall I Owner's equitable share
of such repairs, replacements
and investments, then the
actual equitable share, as
agreed to by Mall I Owner and
H/C I Owner (or, if such
parties cannot agree, as
determined by the Independent
Expert) shall be deemed to be
Mall I Owner's "Proportionate
Schedule "15" - Page 4
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
Share" for purposes of
calculating the amount
described in the foregoing
clause (y).
Water $120,000 for 2004, adjusted Same as Mall I Owner's Share,
annually thereafter based on subject to adjustment by the
the percentage increase, if any, ratio of (a) Gross Leasable
in amounts charged by the Square Footage of the Mall II
applicable water providers and Property (including Level 92'
transporters from the first day Retail Space and the
of the prior Accounting Period Walgreen's Air Rights Parcel)
to the first day of the (b) Gross Leasable Square
applicable Accounting Period Footage of the Mall I Property.
(assuming no change in the
amount of water provided).
Sewer $96,000 for 2004, adjusted Same as Mall I Owner's Share,
annually thereafter based on subject to adjustment by the
the percentage increase, if any, ratio of (a) Gross Square
in the amounts charged by the Footage of the Mall II Property
applicable utility companies (including Level 92' Retail
from the first day of the prior Space and the Walgreen's Air
Accounting Period to the last Rights Parcel) (b) Gross
day of the applicable Square Footage of the Mall I
Accounting Period. Property.
CAM Electric $240,000 for 2004, adjusted Same as Mall I Owner's Share,
annually thereafter based on subject to adjustment by the
the percentage increase, if any, ratio of (a) Gross Common
in the amounts charged by the Area Square Footage of the
applicable electricity providers Mall II Property (including
and transporters from the first Level 92' Retail Space and the
day of the prior Accounting Walgreen's Air Rights Parcel)
Period to the first day of the (b) Gross Common Area
applicable Accounting Period Square Footage of the Mall I
(assuming no change in the Property.
amount of electricity
provided).
Legal/Accounting If it is reasonably necessary Same as Mall I Owner's Share.
for, or if Mall I Owner
requests, H/C I Owner to
perform, or engage third
parties to perform, legal or
Schedule "15" - Page 5
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
accounting services on behalf
of Mall I Owner, such charges
shall be paid for by Mall I
Owner in an amount equal to
the actual out-of-pocket costs
incurred by H/C I Owner on
account of such services. If
the legal or accounting
services benefit more than one
Owner, the costs shall be
divided equally among the
Owners.
Electric Substation 15% of all such expenditures. 15% of all capital expenditures
capital expenditures related to the Phase II
(i.e., expenditures Electrical Substation,
that, under generally excluding the initial cost of
accepted accounting construction, if any.
principles consistently
applied, cannot be
expensed in the year
in which they are
incurred)
Fire 100% of all costs incurred by Same as Mall I Owner's Share.
Suppression/Sprinkler H/C I Owner in connection
Systems with its obligations under
Section 1(b) of Article V, to the
extent such obligations relate to
those portions of all fire
suppression systems (including
sprinklers) located within the
Mall I Space.
All costs and 100% of such costs. Same as Mall I Owner's Share.
expenses caused by,
attributable to or
necessitated by (i)
Mall I Owner's or any
Mall I Occupant's
moving property in or
out of the Mall I
Space or installation
or removal of
furniture, fixtures or
Schedule "15" - Page 6
EXPENSE ITEM MALL I OWNER'S SHARE MALL II OWNER'S SHARE
------------ -------------------- ---------------------
other property, (ii) the
performance by Mall
I Owner or any Mall I
Occupant of any
Alterations, (iii) the
negligence or willful
misconduct of Mall I
Owner or any Mall I
Occupant or the
agents, employees,
contractors, invitees
and other Permittees
of either of them, (iv)
any breach by Mall I
Owner of the
Agreement, or (v) any
breach by any Phase I
Mall Tenant of its
Lease.
NOTES:
*Whenever any definite amount (subject to CPI Adjustment or any other
adjustment) is set forth on this chart as a payment for a certain category of
expenses, such amount (adjusted for CPI or as otherwise adjusted) shall be due
and payable by Mall I Owner to H/C I Owner without regard to the amount actually
incurred by H/C I Owner in respect of that category of expenses (and thus, no
Supporting Documentation pursuant to Section 3(e) of Article V shall be required
to be provided in connection therewith).
**All specified amounts in Schedule II shall be appropriately pro-rated for 2004
(except for purposes of calculating future CPI Adjustments).
***"CPI Adjustment," as used on this Schedule II, shall be calculated
as follows: Each specified dollar amount that is subject to CPI Adjustment shall
be adjusted as of the first day of each Accounting Period, beginning with the
2005 Accounting Period, by multiplying such dollar amount (as it may have
previously been adjusted pursuant to this sentence) by the percentage that is
the sum of (x) one hundred percent (100%), plus (y) one hundred percent (100%)
of the CPI Increase (as defined in the following sentence). "CPI Increase" shall
mean the percentage increase or decrease, if any, that has occurred in the CPI
from the calendar month which is sixteen months prior to the calendar month in
which the applicable Accounting Period begins to the calendar month which is
four months prior to the calendar month in which the applicable Accounting
Period begins. (For example, if a CPI Adjustment is being calculated for the
Schedule "15" - Page 7
Accounting Period that begins January 1, 2007, the CPI Increase would be the
percentage increase that has occurred in the CPI from September, 2005 to
September, 2006). As so adjusted, such amount will be utilized until the next
CPI Adjustment is calculated as of the first day of the next Accounting Period.
"CPI" means the Consumer Price Index for All Urban Consumers published by the
Bureau of Labor Statistics of the United States Department of Labor, U.S. City
Average, All Items 1982-1984=100, or any successor thereto appropriately
adjusted. If the Consumer Price Index ceases to be published, and there is no
successor thereto, such other index as the parties hereto reasonably agree upon
(or, if they cannot so agree, such other index as the Independent Expert shall
determine in accordance with Article 9), as appropriately adjusted, shall be
substituted for the Consumer Price Index.
****Only applicable during the Sempra Term.
Schedule "15" - Page 8
SCHEDULE "16"
MASTER LEASE AGREEMENT
Schedule "16" - Page 1
SCHEDULE "17"
INTENTIONALLY OMITTED
Schedule "17" - Page 1
SCHEDULE "18"
LEASES
No third party has a right, option or election to lease space in the Phase II
Mall other than those rights, options or elections contained in "Leases" (as
defined in the Phase I Mall Sale Agreement).
Schedule "18" - Page 1
SCHEDULE "19"
GAMING PROVISION FOR LEASES
"Tenant acknowledges that Landlord and the Lido Casino Resort, LLC
and their affiliates are businesses that are or may be subject to privileged
licenses issued by governmental authorities relating to casino gaming ("Gaming
Authorities"). If a corporation, Tenant shall disclose the names of all officers
and directors of Tenant, and unless a publicly traded corporation on a national
stock exchange, Tenant shall disclose to Landlord all ownership interests in
Tenant and all lenders or sources of financing. If requested to do so by
Landlord, Tenant shall obtain any license, qualification, clearance or the like
which shall be requested or required of Tenant by any Gaming Authority or any
regulatory authority having jurisdiction over Landlord or any affiliate of
Landlord. If Tenant fails to satisfy such requirement or if Landlord or any
affiliate of Landlord is directed to cease business with Tenant by any such
authority, or if Landlord shall in good faith determine, in Landlord's
reasonable judgment, that Tenant, or any of its officers, directors, employees,
agents, designees or representatives, or partner, owner, member, or shareholder,
or any lender or financial participant (a) is or might be engaged in, or is
about to be engaged in, any activity or activities, or (b) was or is involved in
any relationship, either of which could or does jeopardize Landlord's business,
reputation or such licenses, or those of its affiliates, or if any such license
is threatened to be, or is, denied, curtailed, suspended or revoked, then Tenant
shall immediately (i) terminate any relationship with the individual or entity
which is the source of the problem, or (ii) cease the activity creating the
problem. If Tenant does not comply with item (i) or (ii) above, then Landlord
(x) may require Tenant to specifically perform such obligation (the parties
recognizing that damages or other remedies would be inadequate under the
circumstances) or (y) may terminate this Lease without liability to either
party; provided, however, if any matter described herein is reasonably
susceptible to cure, Tenant shall have a reasonable time within which to effect
such cure (but in no event longer than the time available to fully comply with
any requirement imposed by any Gaming Authority or any other Requirement) and
Landlord shall not have the right to terminate this Lease during such cure
period."
Schedule "19" - Page 1
SCHEDULE "20"
WORK CONTINUATION AGREEMENT
Schedule "20" - Page 1
EXHIBIT A
STANDARDS DOCUMENT
Exhibit A - Page 2
EXHIBIT B
DEVELOPER'S REPRESENTATION CERTIFICATE
LIDO CASINO RESORT, LLC, a Nevada limited liability company with an
office at 3355 Las Vegas Boulevard South, Room 1C, Xxx Xxxxx, XX 00000
("Developer"), hereby certifies that the representations and warranties of the
undersigned set forth in Section 15.1 of the Agreement by and between Developer,
as Developer, and GGP LIMITED PARTNERSHIP, as Mall II Buyer, dated as
___________, 2004 (the "Agreement") are true and correct in all material
respects as of the date hereof [, except that_______]. This certificate is made
subject to the limitations on scope, liability and survival, limitations on
Developer's knowledge and other matters regarding Developer's representations
and warranties set forth in the Agreement (including, without limitation, in
Sections 15.10 and 15.12 and the definition of "knowledge" or "notice").
Executed as of this day____ of _________, 2004.
LIDO CASINO RESORT, LLC
By: Lido Casino Resort Holding Company, LLC
By: Lido Intermediate Holding Company, LLC
By: Venetian Casino Resort, LLC
By: Las Vegas Sands, Inc.
By:________________________________
Name:
Title:
Exhibit B - Page 1
