EXHIBIT 10.14(d)
UNITED STATES OF AMERICA
DEPARTMENT OF TRANSPORTATION
MARITIME ADMINISTRATION
COOPERATIVE AGREEMENT
PROJECT NUMBER: DTMA91-95-H-00069
MODIFICATION: 0003
TITLE: "Integrated Shipboard Information Technology
Platform (ISIT)"
FUNDING DATA: N/A
RECIPIENT NAME Marine Management Systems
AND ADDRESS: 000 Xxxx Xxxxxx
Xxxxxxxx, XX 00000
AGENCY NAME AND DOT/Maritime Administration
ADDRESS: Office of Acquisition, MAR-380
000 Xxxxxxx Xxxxxx, XX., Xxxx 0000
Xxxxxxxxxx, XX 00000
MODIFICATION Article 10 Modifications
AUTHORITY:
DESCRIPTION:
1. By this modification, Article 7 Period of Performance is hereby extended
from January 11, 1997 through July 11, 1997. The total period of
performance for this project is extended from eighteen months to
twenty-four months.
2. In accordance with Article 13 Payable Milestones, the revised ISIT
Consortium payable milestones are hereby modified to reflect the addition
of five new milestones: 8B, 8C, 9A, 10A, 11A. The attached milestones are
incorporated into this agreement.
3. All other terms and conditions of the Cooperative Agreement remain
unchanged.
DEPARTMENT OF TRANSPORTATION
MARITIME ADMINISTRATION
/s/ Xxxxx X. Xxxx July 10, 1996
-------------------------------------------- -----------------
Xxxxxx X. Xxxx Date:
Contracting Officer
ISIT Consortium
Attachment #4 (Payable Milestones)
Cooperative Agreement DTMA91-95-H-00069
Modification No. 3
Project Payable Milestones
Adjusted for January 1996 and June 12 Schedule
Change
(Milestone 1-7 Unchanged)
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 8A
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development System Requirements Specification - Final Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development TR: Architecture Approach; Cooperating Object
Frameworks
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development TR: Architectural Approaches; Persistence,
Distribution, Concurrency
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.1 ASTM STDS Development Review Draft No. 4; Review & Comment
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board ISO/IMO ISIT Briefings
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
6.2/6.3 Coordinated Business Plan/Strategic Alliances Coordinated Business Plan/Strategic Alliances
1st Draft
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 8A: $75,101
TARGET COMPLETION DATE: MAY 31, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 8B
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.1 Hardware Development Hardware Integration and Integration Test Plan -
2nd Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development System Requirement Specification - Final
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review Meeting No. 4 - Final Design
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 8B: $25,000
TARGET COMPLETION DATE: JUNE 28, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 8C
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.1 Hardware Development Hardware Integration & Integration Test Plan -
Final Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development System Design Document - First Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.1 ASTM Standards Development Rev. Draft No. 4 Submitted for Subcommittee Ballot
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.2 ABS Guidelines Development Final Draft - Review and Comment
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Technical Progress Report No. 4
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 8C: $25,000
TARGET COMPLETION DATE: JULY 26, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 9
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development System Design Document - Final
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.1/4.2 ASTM STDS/ABS Guidelines Development ASTM Review Draft No. 5; Status Report No. 2
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board Advisory Board Meeting No. 4
---------------------------------------------------------------------------------------------------------------------------------
6.2/6.3 Coordinated Business Plan Coordinated Business Plan/Strategic Alliances;
2nd Draft
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 9: $63,971
TARGET COMPLETION DATE: AUGUST 30, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 9A
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development API Document - Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.3 Configuration Management Configuration Management Plan - Final
---------------------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review Meeting No. 5
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 9A: $58,000
TARGET COMPLETION DATE: SEPTEMBER 20, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 10
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
2.2 Software Development API Document - Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.1 System Integration & Test Land-Based Test Plan - Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.2 ABS Guidelines Development Final Draft; for Review by ABS Committees
---------------------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Technical Progress Report No. 5
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
6.2 Coordinated Business Plan Commercialization Plan
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
6.3 Strategic Alliances Commercialization Plan
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 10: $69,097
TARGET COMPLETION DATE: OCTOBER 25, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 10A
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.1 System Integrating & Test System Integration Test Plan - Draft
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
7.1 Demonstration Test Plan Demonstration Test Plan - Draft
---------------------------------------------------------------------------------------------------------------------------------
7.2 Demonstration Design Demonstration Design - Draft
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 10A: $46,064
TARGET COMPLETION DATE: NOVEMBER 29, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 11
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.1 System Integration and Test Land Based Test Plan - Final
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review No. 6 - Test Readiness
---------------------------------------------------------------------------------------------------------------------------------
7.1 Demonstration Test Plan Demonstration Test Plan - Final
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 11: $71,219
TARGET COMPLETION DATE: DECEMBER 30, 1996
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 11A
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.1 ASTM Standards Development F25 Ballot Complete
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
4.2 ABS Guidelines Development Pre-Release Draft
---------------------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Technical Progress Report No. 6
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board Advisory Board Meeting No. 5
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 11A: $47,480
TARGET COMPLETION DATE: JANUARY 24, 1997
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 12
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.1 System Integration & Test System Integration and Test Report - Preliminary
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Data Acquisition
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Executive
---------------------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Test Report, Communication Services
---------------------------------------------------------------------------------------------------------------------------------
7.2 Demonstration Design Demonstration Design - Final
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 12: $149,529
TARGET COMPLETION DATE: MARCH 21, 1997
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 13
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.1 System Integration and Test System Integration Test Report - Final
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
3.2 Land Based Testing Land Based Test Report - Final
---------------------------------------------------------------------------------------------------------------------------------
5.2 Technical Review Technical Review Meeting No. 7; Final
Presentation; Phase I
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Progress Report No. 7
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
7.3 Demonstration Install/Checkout Shipboard Installation/Checkout Complete
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
7.4 Demonstration Install/Checkout Shore side Installation/Checkout Complete
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 13A: $65,247
TARGET COMPLETION DATE: APRIL 18, 1997
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 14
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.5 Industry Interface/Advisory Board Advisory Board Meeting No. 6
---------------------------------------------------------------------------------------------------------------------------------
7.5 Demonstration Test Demonstration Test Preliminary Report
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 14: $53,190
TARGET COMPLETION DATE: MAY 23, 1997
---------------------------------------------------------------------------------------------------------------------------------
MILESTONE NUMBER 15
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK DESCRIPTION MEASURE OF COMPLETION
---------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
5.3 Management Reports Final Project Report
---------------------------------------------------------------------------------------------------------------------------------
7.5 Demonstration Test Demonstration Assessment Report
---------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYABLE AMOUNT; MILESTONE 15: $60,868
TARGET COMPLETION DATE: JUNE 20, 1997
