1
EXHIBIT 10.20
INDUSTRIAL/COMMERCIAL SINGLE-TENANT LEASE NET
1. BASIC PROVISIONS ("BASIC PROVISIONS").
1.1. PARTIES:
This Lease ("Lease"), dated for reference purposes only, November 15,
1999, is made by and between - CHAMPAGNE BUILDING GROUP, LP, a
California limited partnership ("LESSOR") or ("LANDLORD") and SKECHERS
USA, INC., a Delaware Corporation ("LESSEE" or "TENANT"), (collectively
the "PARTIES," or individually a "PARTY").
1.2. PREMISES:
That certain real property, including the "BASE BUILDING" as defined in
the Work Letter attached hereto as Exhibit A to be provided by Lessor
under the terms of this Lease, plus those improvements to be separately
constructed by Tenant pursuant to the Work Letter (the "TENANT
IMPROVEMENTS") together with the land described in the legal description
attached hereto as "LEGAL DESCRIPTION" and commonly known as 0000 X.
Xxxxxxxxx Xxxxxx, Xxxxxxx located in the County of San Bernardino, State
of California and generally described as an approximate 263,670 square
foot free standing distribution building (all of such real property,
including, without limitation, such land, all improvements upon such
land, the Base Building and Tenant Improvements are collectively
referred to herein as the "PREMISES"). (See also Paragraph 2)
1.3. TERM:
Seven (7)years and Zero (0) months ("ORIGINAL TERM") commencing upon
Substantial Completion (as defined in the Addendum) ("COMMENCEMENT
DATE") and ending Seven years after the Commencement Date ("EXPIRATION
DATE"). Landlord agrees that Substantial Completion, and therefore, the
Commencement Date, shall be hot later than May 15, 2000 (the "SCHEDULED
COMMENCEMENT DATE") subject to Force Majeure Delays (as defined in the
Addendum) (See also Paragraph 3)
1.4. EARLY POSSESSION:
March 15, 2000 or as agreed subject to Force Majeure Delays ("EARLY
POSSESSION DATE"). (See also Paragraphs 3.2 and 3.3)
1.5. BASE RENT:
$85,693.00 per month ("BASE RENT"), payable on the first day of each
month commencing the first day following Substantial Completion (See
also Paragraph 4)
1
2
[x] If this box Is checked, there are provisions in this Lease for the
Base Rent to be adjusted (see Addendum Paragraph 50)
1.6. BASE RENT PAID UPON EXECUTION:
$85,693.00 as Base Rent for the period: first month's rent
1.7. SECURITY DEPOSIT:
$85,693.00 ("Security Deposit") in addition to the Base Rent Paid Upon
Execution. (See also Paragraph 5)
1.8. AGREED USE:
Warehousing, distribution, office and showroom and uses reasonably
related to the foregoing (See also Paragraph 6)
1.9. INSURING PARTY:
Lessor is the "Insuring Party" unless otherwise stated herein. (See also
Paragraph 8)
1.10. REAL ESTATE BROKERS:
(See also Paragraph 15)
(a) Representation: The following real estate brokers
(collectively, the "Brokers") and brokerage relationships exist in this
transaction (check applicable boxes):
[x] The Xxxxxx Company represents Lessor exclusively ("Lessor's
Broker");
[x] CB Xxxxxxx Xxxxx represents Lessee exclusively ("Lessee's Broker")
(b) Payment to Brokers: Upon execution and delivery of this
Lease by both Parties, Lessor shall pay to the Broker the fee agreed to
in their separate written agreement
1.11. GUARANTOR.
The obligations of the Lessee under this Lease are to be guaranteed by
N/A ("Guarantor"). (See also Paragraph 37)
1.12. ADDENDA AND EXHIBITS.
Attached hereto is an Addendum or Addenda consisting of Paragraphs 50
through 65, the Legal Description, and Exhibits A (Work Letter) and B
(Protected Lessee Owned Alterations) all of which constitute a part of
this Lease.
2. PREMISES.
2.1. LETTING.
2
3
Lessor hereby leases to Lessee, and Lessee hereby leases from Lessor,
the Premises, for the term, at the rental, and upon all of the terms,
covenants and conditions set forth in this Lease. Unless otherwise
provided herein, any statement of size set forth in this Lease, or that
may have been used in calculating rental, is an approximation which the
Parties agree is reasonable and the rental based thereon is not subject
to revision whether or not the actual size is more or less.
2.2. CONDITION.
Lessor shall deliver the Base Building (as defined in the Work Letter,
and sometimes referred to herein as the "Building") to Lessee broom
clean and free of debris (except dirt and debris caused by Tenant) on
the Commencement Date, and, so long as the required service contracts
described in Paragraph 7.1 (b) below are obtained by Lessee within
thirty (30) days following the Commencement Date, Lessor warrants that
the Base Building, including, without limitation, existing electrical,
plumbing, fire sprinkler, lighting, heating, ventilating and air
conditioning systems ("HVAC"), loading doors, if any, and all other such
elements in the Premises, other than those constructed by Lessee, shall
be in good operating condition on said date and shall be free of
material defects. Notwithstanding Lessee's failure to obtain such
required service contracts within thirty (30) days following the
Commencement Date, the Lessor warranty described in the foregoing
sentence shall nevertheless continue so long as Lessee has obtained all
of such required service contracts within ten (10) days following notice
from Lessor subsequent to such thirty (30) day period to the effect that
Lessee has not obtained such required service contracts (the "Service
Contract Deficiency Notice") and must do so within ten (10) days of such
Service Contract Deficiency Notice or Lessor will be relieved of the
Lessor warranty described in the first sentence of Paragraph 2.2 of the
Lease. If a non-compliance with said warranty exists as of the
Commencement Date, Lessor shall, as Lessor's sole obligation with
respect to such matter, except as otherwise provided in this Lease,
promptly after receipt of written notice from Lessee setting forth with
specificity the nature and extent of such non-compliance, rectify same
at Lessor's expense. If, after the Commencement Date, Lessee does not
give Lessor written notice of any non-compliance with this warranty
within: (i) five (5) years as to the roof and the structural portion of
the roof, (ii) two (2) years as to the slab and concrete walls, and
(iii) one (1) year as to the remaining systems and other elements of the
Building, correction of such non-compliance shall be the obligation of
Lessee at Lessee's sole cost and expense; provided, however, that
Lessee's sole obligation with respect to the items specified in
subsections (i)(iii) of this sentence shall not commence unless and
until Lessor has given to Lessee notice that as to such applicable
subsection Lessor's obligations are ending or have ended and Lessee's
obligations are beginning or have begun. Lessor's obligations with
respect to any warranties given to Lessee pursuant to this Section 2.2
are conditioned upon the following: (a) Lessee shall have given notice
to Lessor of any claims on such warranties promptly and in no event not
later than twenty (20) days after the discovery of the condition giving
rise to such claim and (b) except in connection with an emergency that
threatens property or safety, if Lessee or any person other than a
person selected by Lessor repairs or otherwise attempts to correct an
conditions giving rise to the claim, Lessor shall be relieved of the
warranty obligations related to such condition repaired or corrected by
such other person.
2.3. COMPLIANCE.
3
4
Lessor warrants that the improvements on the Premises comply with all
applicable laws, covenants or restrictions of record, building codes,
regulations and ordinances ("Applicable Requirements") in effect on the
Commencement Date. Said warranty does not apply to the use to which
Lessee will put the Premises or to any Alterations or Utility
Installations (as defined in Paragraph 7.3(a)) made or to be made by
Lessee. NOTE: Lessee is responsible for determining whether or not the
zoning is appropriate for Lessee's intended use, and acknowledges that
past uses of the Premises may no longer be allowed. If the Premises do
not comply with said warranty, Lessor shall, except as otherwise
provided, promptly after receipt of written notice from Lessee setting
forth with specificity the nature and extent of such non-compliance,
rectify the same at Lessor's expense. If Lessee does not give Lessor
written notice of a non-compliance with this warranty within six (6)
months following the Commencement Date, correction of that
non-compliance shall be the obligation of Lessee at Lessee's sole cost
and expense. If the Applicable Requirements are hereafter changed (as
opposed to being in existence at the Commencement Date) so as to require
during the term of this Lease the construction of an addition to or an
alteration of the Building, the remediation of any Hazardous Substance,
or the reinforcement or other physical modification of the Building
("Capital Expenditure"), Lessor and Lessee shall allocate the cost of
such work as follows:
(a) Subject to Paragraph 2.3(c) below, if such Capital Expenditures are
required as a result of the specific and unique use of the Premises
by Lessee as compared with uses by tenants in general, Lessee shall
be fully responsible for the cost thereof, provided, however, that
if such Capital Expenditure is required during the last two (2)
years of this Lease and the cost thereof exceeds six (6) months'
Base Rent, Lessee may instead terminate this Lease unless Lessor
notifies Lessee, in writing, within ten (10) days after receipt of
Lessee's termination notice that Lessor has elected to pay the
difference between the actual cost thereof and the amount equal to
six (6) months' Base Rent. If Lessee elects termination, Lessee
shall immediately cease the use of the Premises which requires such
Capital Expenditure and deliver to Lessor written notice specifying
a termination date at least ninety (90) days thereafter. Such
termination date shall, however, in no event be earlier than the
last day that Lessee could legally utilize the Premises without
commencing such Capital Expenditure.
(b) If such Capital Expenditure is not the result of the specific and
unique use of the Premises by Lessee (such as, governmentally
mandated seismic modifications), then Lessor and Lessee shall
allocate the obligation to pay for such costs pursuant to the
provisions of Paragraph 7.1 (c); provided, however, that if such
Capital Expenditure is required during the last two years of this
Lease or if Lessor reasonably determines that it is not economically
feasible to pay its share thereof, Lessor shall have the option to
terminate this Lease upon ninety (90) days prior written notice to
Lessee unless Lessee notifies Lessor, in writing, within ten (10)
days after receipt of Lessor's termination notice that Lessee will
pay for such Capital Expenditure. It Lessor does not elect to
terminate, and fails to tender its share of any such Capital
Expenditure, Lessee may advance such funds and deduct same, with
interest, from Rent until Lessors share of such costs have been
fully paid. If Lessee is unable to finance Lessor's share, or if the
balance of the Rent due and payable for the remainder of this Lease
is not sufficient to fully reimburse Lessee on
4
5
an offset basis, Lessee shall have the right to terminate this
Lease upon thirty (30) days written notice to Lessor.
(c) Notwithstanding the above, the provisions concerning Capital
Expenditures are intended to apply only to non-voluntary,
unexpected, and new Applicable Requirements. If the Capital
Expenditures are instead triggered by Lessee as a result of an
actual or proposed change in use, change in intensity of use, or
modification to the Premises then, and in that event, Lessee shall
be fully responsible for the cost thereof, and Lessee shall not have
any right to terminate this Lease.
2.4. ACKNOWLEDGEMENTS.
[intentionally omitted]
2.5. LESSEE AS PRIOR OWNER/OCCUPANT.
[intentionally omitted]
3. TERM.
3.1. TERM.
The Commencement Date, Expiration Date and Original Term of this Lease
are as specified in Paragraph 1.3.
3.2. EARLY POSSESSION.
If Lessee totally or partially occupies the Premises prior to the
Commencement Date, the obligation to pay Base Rent shall be abated for
the period of such early possession. All other terms of this Lease
(including, but not limited to, the obligations to pay Real Property
Taxes and insurance premiums and to maintain the Premises) shall,
however, be in effect during such period. Any such early possession
shall not affect the Expiration Date.
3.3. DELAY IN POSSESSION.
(See Addendum Paragraph 61)
3.4. LESSEE COMPLIANCE.
Lessor shall not be required to tender possession of the Premises to
Lessee until Lessee complies with its obligation to provide evidence of
insurance (Paragraph 8.5). Pending delivery of such evidence, Lessee
shall be required to perform all of its obligations under this Lease
from and after the Commencement Date, including the payment of Rent,
notwithstanding Lessor's election to withhold possession pending receipt
of such evidence of insurance. Further, if Lessee is required to perform
any other conditions prior to or concurrent with the Early Possession
Date, the Early Possession Date shall occur but Lessor may elect to
withhold possession until such conditions are satisfied.
5
6
4. RENT.
4.1. RENT DEFINED.
All monetary obligations of Lessee to Lessor under the terms of this
Lease (except for the Security Deposit) are deemed to be rent ("RENT").
4.2. PAYMENT.
Lessee shall cause payment of Rent to be received by Lessor in lawful
money of the United States, without offset or deduction (except as
specifically permitted in this Lease), on or before the day on which it
is due. Rent for any period during the term hereof which is for less
than one (1) full calendar month shall be prorated based upon the actual
number of days of said month. Payment of Rent shall be made to Lessor at
its address stated herein or to such other persons or place as Lessor
may from time to time designate in writing. Acceptance of a payment
which is less than the amount then due shall not be a waiver of Lessor's
rights to the balance of such Rent, regardless of Lessors endorsement of
any check so stating.
5. SECURITY DEPOSIT.
Lessee. shall deposit with Lessor upon execution hereof the Security
Deposit as security for Lessee's faithful performance of its obligations
under this Lease. If Lessee fails to pay Rent, or otherwise Defaults
under this Lease, Lessor may use, apply or retain all or any portion of
said Security Deposit for the payment of any amount due Lessor or to
reimburse or compensate Lessor for any liability, expense, loss or
damage which Lessor may suffer or incur by reason thereof. If Lessor
uses or applies all or any portion of said Security Deposit, Lessee
shall within ten (10) days after written request therefor deposit monies
with Lessor sufficient to restore said Security Deposit to the full
amount required by this Lease. If the Base Rent increases during the
term of this Lease, Lessee shall, upon written request from Lessor,
deposit additional monies with Lessor so that the total amount of the
Security Deposit shall at all times bear the same proportion to the
increased Base Rent as the initial Security Deposit bore to the initial
Base Rent. Should the Agreed Use be amended to accommodate a material
change in the business of Lessee or to accommodate a sublessee or
assignee, Lessor shall have the right to increase the Security Deposit
to the extent necessary, In Lessor's reasonable judgment, to account for
any increased wear and tear that the Premises may suffer as a result
thereof. If a change in control of Lessee occurs during this Lease and
following such change the financial condition of Lessee is, in Lessor's
reasonable judgment, significantly reduced, Lessee shall deposit such
additional monies with Lessor as shall be sufficient to cause the
Security Deposit to be at a commercially reasonable level based on said
change in financial condition. Lessor shall not be required to keep the
Security Deposit separate from its general accounts. Within fourteen
(14) days after the expiration or termination of this Lease, if Lessor
elects to apply the Security Deposit only to unpaid Rent, and otherwise
within thirty (30) days after the Premises have been vacated pursuant to
Paragraph 7.4(c) below, Lessor shall return that portion of the Security
Deposit not used or applied by Lessor. No part of the Security Deposit
shall be considered to be held in trust, to bear interest (except as
hereinafter set forth)
6
7
or to be prepayment for any monies to be paid by Lessee under this
Lease. Upon the return of the unused amounts of the Security Deposit,
Lessor shall pay to Lessee an amount equal to simple (not compounded)
interest on the portions of the Security Deposit unused from time to
time during the Term. Lessor shall make such interest calculations on a
monthly basis (using a 30 day month) using a simple interest rate of
five (5%).
6. USE.
6.1. USE.
Lessee shall use and occupy the Premises only for the Agreed Use, or any
other legal use which is reasonably comparable thereto, and for no other
purpose. Lessee shall not use or permit the use of the Premises in a
manner that is unlawful, creates damage, waste or a nuisance, or that
disturbs owners and/or occupants of, or causes damage to neighboring
properties. Lessor shall not unreasonably withhold or delay its consent
to any written request for a modification of the Agreed Use, so long as
the same will not impair the structural integrity of the improvements on
the Premises or the mechanical or electrical systems therein, is not
significantly more burdensome to the Premises. If Lessor elects to
withhold consent, Lessor shall within five (5) business days after such
request give written notification of same, which notice shall include an
explanation of Lessor's objections to the change in use.
6.2. HAZARDOUS SUBSTANCES.
(a) REPORTABLE USES REQUIRE CONSENT. The term "HAZARDOUS
SUBSTANCE" as used in this Lease shall mean any product, substance, or
waste whose presence, use, manufacture, disposal, transportation, or
release, either by itself or in combination with other materials
expected to be on the Premises, is either: (i) potentially injurious to
the public health, safety or welfare, the environment or the Premises,
(ii) regulated or monitored by any governmental authority, or (iii) a
basis for potential liability of Lessor to any governmental agency or
third party under any applicable statute or common law theory. Hazardous
Substances shall include, but not be limited to, hydrocarbons,
petroleum, gasoline, and/or crude oil or any products, by-products or
fractions thereof. Lessee shall not engage in any activity in or on the
Premises which constitutes a Reportable Use of Hazardous Substances
without the express prior written consent of Lessor and timely
compliance (at Lessee's expense) with all Applicable Requirements.
"REPORTABLE USE" shall mean (1) the installation or use of any above or
below ground storage tank, (2) the generation, possession, storage, use,
transportation, or disposal of a Hazardous Substance that requires a
permit from, or with respect to which a report, notice, registration or
business plan is required to be filed with, any governmental authority,
and/or (3) the presence at the Premises of a Hazardous Substance with
respect to which any Applicable Requirements requires that a notice be
given to persons entering or occupying the Premises or neighboring
properties. Notwithstanding the foregoing, Lessee may use any ordinary
and customary materials reasonably required to be used in the normal
course of the Agreed Use, so long as such use is in compliance with, all
Applicable Requirements, is not a Reportable Use, and does not expose
the Premises or neighboring property to any meaningful risk of
contamination or damage or expose Lessor to any liability therefor. In
addition, Lessor may condition its consent to any Reportable Use upon
receiving such additional assurances as Lessor reasonably deems
necessary to protect
7
8
itself, the public, the Premises and/or the environment against damage,
contamination, injury and/or liability, including, but not limited to,
the installation (and removal on or before Lease expiration or
termination) of protective modifications (such as concrete encasements)
and/or increasing the Security Deposit.
(b) DUTY TO INFORM LESSOR. If Lessee knows, or has reasonable
cause to believe, that a Hazardous Substance has come to be located in,
on, under or about the Premises, other than as previously consented to
by Lessor, Lessee shall immediately give written notice of such fact to
Lessor, and provide Lessor with a copy of any report, notice, claim or
other documentation which it has concerning the presence of such
Hazardous Substance.
(c) LESSEE REMEDIATION. Lessee shall not cause or permit any
Hazardous Substance to be spilled or released in, on, under, or about
the Premises (including through the plumbing or sanitary sewer system)
and shall promptly, at Lessee's expense, take all investigatory and/or
remedial action reasonably recommended, whether or not formally ordered
or required, for the cleanup of any contamination of, and for the
maintenance, security and/or monitoring of the Premises or neighboring
properties, that was caused or materially contributed to by Lessee, or
pertaining to or involving any Hazardous Substance brought onto the
Premises during the term of this Lease, by or for Lessee, or any third
party. Notwithstanding the foregoing, Lessee shall have no liability
under this Lease with respect to underground migration of any Hazardous
Substance under the Premises from adjacent properties unless such
adjacent properties are owned or occupied by Lessee, and then only to
the extent caused by Lessee.
(d) LESSEE INDEMNIFICATION. Lessee shall indemnify, defend and
hold Lessor, its agents, employees, lenders and ground lessor, if any,
harmless from and against any and all loss of rents and/or damages,
liabilities, judgments, claims, expenses, penalties, and attorneys' and
consultants' fees arising out of or involving any Hazardous Substance
brought onto the Premises by or for Lessee, or any third party
(provided, however, that Lessor shall have no liability under this Lease
with respect to underground migration of any Hazardous Substance under
the Premises from adjacent properties occurring after the Commencement
Date). Lessee's obligations shall include, but not be limited to, the
effects of any contamination or injury to person, property or the
environment created or suffered by Lessee, and the cost of
investigation, removal, remediation, restoration and/or abatement, and
shall survive the expiration or termination of this Lease. No
termination, cancellation or release agreement entered into by Lessor
and Lessee shall release Lessee from its obligations under this Lease
with respect to Hazardous Substances, unless specifically so agreed by
Lessor in writing at the time of such agreement
(e) LESSOR INDEMNIFICATION. Lessor and its successors and
assigns shall indemnify, defend, reimburse and hold Lessee, its
employees and lenders, harmless from and against any and all damages,
liabilities, judgments, claims, expenses, penalties, and attorneys' and
consultants' fees and all environmental damages, including the cost of
remediation, arising out of or involving any Hazardous Substances on the
Premises prior to the Commencement Date or which are caused by the
gross negligence or willful misconduct of Lessor, its agents or
employees. Lessor's obligations, as and when required by the Applicable
Requirements, shall include, but not be limited to, the cost of
investigation, removal, remediation, restoration and/or abatement, and
shall survive the expiration or termination of this Lease. No
termination, cancellation or release agreement entered into by Lessor
and Lessee shall release Lessor from its obligations under this Lease
with respect to Hazardous Substances, unless specifically so agreed by
Lessee in writing at the time of such agreement.
8
9
(f) INVESTIGATIONS AND REMEDIATIONS. Lessor shall retain the
responsibility and pay for any investigations or remediation measures
required by governmental entities having jurisdiction with respect to
the existence of Hazardous Substances on the Premises prior to the
Commencement Date, unless such remediation measure is required as a
result of Lessee's use (including "Alterations", as defined in Paragraph
7.3(a) below) of the Premises, in which event Lessee shall be
responsible for such payment. Lessee shall cooperate fully in any such
activities at the request of Lessor, including allowing Lessor and
Lessor's agents to have reasonable access to the Premises at reasonable
times in order to carry out Lessor's investigative and remedial
responsibilities.
(g) LESSOR TERMINATION OPTION. If a Hazardous Substance
Condition occurs during the term of this Lease, unless Lessee is legally
responsible therefor (in which case Lessee shall make the investigation
and remediation thereof required by the Applicable Requirements and this
Lease shall continue in full force and effect, but subject to Lessor's
rights under Paragraph 6.2(d) and Paragraph 13), Lessor may, at Lessor's
option, either (i) investigate and remediate such Hazardous Substance
Condition, if required, as soon as reasonably possible at Lessors
expense, in which event this Lease shall continue in full force and
effect, or (ii) if the estimated cost to remediate such condition
exceeds twelve (12) times the then monthly Base Rent or $100,000,
whichever is greater, give written notice to Lessee, within thirty (30)
days after receipt by Lessor of knowledge of the occurrence of such
Hazardous Substance Condition, of Lessor's desire to terminate this
Lease as of the date sixty (60) days following the date of such notice.
In the event Lessor elects to give a termination notice, Lessee may,
within ten (10) days thereafter, give written notice to Lessor of
Lessee's commitment to pay the amount by which the cost of the
remediation of such Hazardous Substance Condition exceeds an amount
equal to twelve (12) times the then monthly Base Rent or $100,000,
whichever is greater, Lessee shall provide Lessor with said funds or
satisfactory assurance thereof within thirty (30) days following such
commitment. In such event, this Lease shall continue in full force and
effect, and Lessor shall proceed to make such remediation as soon as
reasonably possible after the required funds are available. If Lessee
does not give such notice and provide the required funds or assurance
thereof within the time provided, this Lease shall terminate as of the
date specified in Lessor's notice of termination.
6.3. LESSEE'S COMPLIANCE WITH APPLICABLE REQUIREMENTS.
Except as otherwise provided in this Lease (and, in particular,
Paragraphs 2.2 and 2.3 hereof), Lessee shall, at Lessee's sole expense,
fully, diligently and in a timely manner, materially comply with all
Applicable Requirements, and the requirements of any applicable fire
insurance underwriter or rating bureau, without regard to whether said
requirements are now in effect or become effective after the Early
Possession Date. Lessee shall, within ten (10) days after receipt of
Lessor's written request, provide Lessor with copies of all permits and
other documents, and other information evidencing Lessee's compliance
with any Applicable Requirements specified by Lessor, and shall
immediately upon receipt, notify Lessor in writing (with copies of any
documents involved) of any threatened or actual claim, notice, citation,
warning, complaint or report pertaining to or involving the failure of
Lessee or the Premises to comply with any Applicable Requirements.
9
10
6.4. INSPECTION; COMPLIANCE.
Lessor and Lessor's "Lender" (as defined in Paragraph 30 below) and
consultants shall have the right to enter into Premises at any time, in
the case of an emergency, and otherwise at reasonable times, for the
purpose of inspecting the condition of the Premises and for verifying
compliance by Lessee with this Lease. The cost of any such inspections
shall be paid by Lessor, unless a violation of Applicable Requirements,
or a contamination is found to exist or be imminent, or the inspection
is requested or ordered by a governmental authority. In such case,
Lessee shall upon request reimburse Lessor for the cost of such
inspections, so long as such inspection is reasonably related to the
violation or contamination.
7. MAINTENANCE; REPAIRS, UTILITY INSTALLATIONS; TRADE FIXTURES AND ALTERATIONS.
7.1. LESSEE's OBLIGATIONS.
(a) IN GENERAL. Subject to the provisions of Paragraph 2.2
(Condition), 2.3 (Compliance), 6.3 (Lessee's Compliance with Applicable
Requirements), 7.2 (Lessor's Obligations), 9 (Damage or Destruction), 14
(Condemnation), and the Work Letter (which provisions shall control over
any conflicting provisions in this Paragraph 7.1 (a)), Lessee shall, at
Lessee's sole expense, keep the Premises, Utility Installations, and
Alterations in good order, condition and repair (whether or not the
portion of the Premises requiring repairs, or the means of repairing the
same, are reasonably or readily accessible to Lessee, and whether or not
the need for such repairs occurs as a result of Lessee's use, any prior
use, the elements or the age of such portion of the Premises),
including, but not limited to, all equipment or facilities, such as
plumbing, heating, ventilating, air-conditioning, electrical, lighting
facilities, boilers, pressure vessels, fire protection system, fixtures,
walls (interior and exterior), foundations, ceilings, roofs, floors,
windows, doors, plate glass, skylights, landscaping, driveways, parking
lots, fences, retaining walls, signs, sidewalks and parkways located in,
on, or adjacent to the Premises. Lessee, in keeping the Premises in good
order, condition and repair, shall exercise and perform good,
maintenance practices, specifically including the procurement and
maintenance of the service contracts required by Paragraph 7.1 (b)
below. Lessee's obligations shall include restorations, replacements or
renewals when necessary to keep the Premises and all improvements
thereon or a part thereof in good order, condition and state of repair.
Lessee shall, during the term of this Lease, keep the exterior
appearance of the Building in a first-class condition consistent with
the exterior appearance of other similar facilities of comparable age
and size in the vicinity, including, when necessary, the exterior
repainting of the Building. Lessor shall non-exclusively assign to
Lessee all warranties obtained by Lessor related to the Base Building.
(b) SERVICE CONTRACTS. Lessee shall, at Lessee's sole expense,
procure and maintain contracts, with copies to Lessor, in customary form
and substance for, and with contractors specializing and experienced in
the maintenance of the following equipment and improvements, if any, if
and when installed on the Premises (the "BASIC ELEMENTS"): (i) HVAC
equipment, (ii) boiler, and pressure vessels, (iii) fire extinguishing
systems, including fire alarm and/or smoke detection, (iv) landscaping
and irrigation systems, (v) roof covering and drains, (vi) driveways and
parking lots, (vii) clarifiers (viii) basic utility feed to the
perimeter of the Building, and (ix) any other equipment, if reasonably
required by Lessor.
10
11
(c) REPLACEMENT. Subject to Lessee's indemnification of Lessor
as set forth in Paragraph 8.7 below, and without relieving Lessee of
liability resulting from Lessee's failure to exercise and perform good
maintenance practices, if the Basic Elements described in Paragraph 7.1
(b) cannot be repaired other than at a cost which is in excess of 50% of
the cost of replacing such Basic Elements, then such Basic Elements
shall be replaced by Lessor, and the cost thereof shall be prorated
between the Parties and Lessee shall only be obligated to pay, each
month during the remainder of the term of this Lease, on the date on
which Base Rent is due, an amount equal to the product of multiplying
the cost of such replacement by a fraction, the numerator of which is
one, and the denominator of which is the number of months of the useful
life of such replacement as such useful life is specified pursuant to
Federal income tax regulations or guidelines for depreciation thereof
(including interest on the unamortized balance as is then commercially
reasonable in the judgment of Lessor's accountants), with Lessee
reserving the right to prepay its obligation at any time.
7.2. LESSOR's OBLIGATIONS.
Subject to the provisions of Paragraphs 2.2 (Condition), 2.3
(Compliance), 9 (Damage or Destruction) and 14 (Condemnation), it is
intended by the Parties hereto that Lessor have no obligation, in any
manner whatsoever, to repair and maintain the Premises, or the equipment
therein, all of which obligations are intended to be that of the Lessee.
It is the intention of the Parties that the terms of this Lease govern
the respective obligations of the Parties as to maintenance and repair
of the Premises, and they expressly waive the benefit of any statute now
or hereafter in effect to the extent it is inconsistent with the terms
of this Lease.
7.3. UTILITY INSTALLATIONS; TRADE FIXTURES; ALTERATIONS.
(a) DEFINITIONS; CONSENT REQUIRED. The term "UTILITY
INSTALLATIONS" refers to all floor ad window coverings, air lines, power
panels, electrical distribution, security and fire protection systems,
communication systems, lighting fixtures, HVAC equipment, plumbing, and
fencing in or on the Premises. The term "TRADE FIXTURES" shall mean
Lessee's machinery and equipment that can be removed without doing
material damage to the Premises. The term "ALTERATIONS" shall mean any
modification of the improvements, other than Utility Installations or
Trade Fixtures, whether by addition or deletion. "LESSEE OWNED
ALTERATIONS AND/OR UTILITY INSTALLATIONS" are defined as Alterations
and/or Utility Installations made by Lessee that are not yet owned by
Lessor pursuant to Paragraph 7.4(a). Lessee shall not make any
Alterations or Utility Installations to the Premises without Lessor's
prior written consent. Lessee may, however, make non-structural Utility
Installations to the interior of the Premises (excluding the roof)
without such consent but upon notice to Lessor, as long as they are not
visible from the outside, do not involve puncturing, relocating or
removing the roof or any existing walls, and the cumulative cost thereof
during this Lease as extended does not exceed $50,000 in the aggregate
or $10,000 in any one year.
(b) CONSENT. Any Alterations or Utility Installations that
Lessee shall desire to make and which require the consent of the Lessor
shall be presented to Lessor in written form with detailed plans.
Consent shall be deemed conditioned upon Lessee's: (i) acquiring all
applicable governmental permits, (ii) furnishing Lessor with copies of
both the permits and the plans and specifications prior to commencement
of the work, and (iii) compliance with all conditions of
11
12
said permits and other Applicable Requirements in a prompt and
expeditious manner. Any Alterations or Utility Installations shall be
performed in a workmanlike manner with good and sufficient materials.
Lessee shall promptly upon completion furnish Lessor with as-built plans
and specifications. For work which costs an amount equal to the greater
of one month's Base Rent, or $10,000, Lessor may condition its consent
upon Lessee providing a lien and completion bond in an amount equal to
one and one-half times the estimated cost of such Alteration or Utility
Installation and/or upon Lessee's posting an additional Security Deposit
with Lessor.
(c) INDEMNIFICATION. Lessee shall pay, when due, all claims for
labor or materials furnished or alleged to have been furnished to or for
Lessee at or for use on the Premises, which claims are or may be secured
by any mechanic's or materialmen's lien against the Premises or any
interest therein. Lessee shall give Lessor not less than ten (10) days'
notice prior to the commencement of any work in, on or about the
Premises, and Lessor shall have the right to post notices of
non-responsibility. If Lessee shall contest the validity of any such
lien, claim or demand, then Lessee shall, at its sole expense defend and
protect itself, Lessor and the Premises against the same and shall pay
and satisfy any such adverse judgment that may be rendered thereon
before the enforcement thereof. If Lessor shall require, Lessee shall
furnish a surety bond in an amount equal to one and one-half times the
amount of such contested lien, claim or demand, indemnifying Lessor
against liability for the same. If Lessor elects to participate in any
such action, Lessee shall pay Lessor's attorneys' fees and costs.
7.4. OWNERSHIP; REMOVAL; SURRENDER; AND RESTORATION.
(a) OWNERSHIP. Subject to Lessor's right to require removal or
elect ownership as hereinafter provided, all Alterations and Utility
Installations made by Lessee shall be the property of Lessee, but
considered a part of the Premises. Lessor may, at any time, elect in
writing to be the owner of all or any specified part of the Lessee Owned
Alterations and Utility Installations except for those items listed on
Exhibit B ("Protected Lessee Owned Alterations"). Unless otherwise
instructed per Paragraph 7.4(b) hereof, all Lessee Owned Alterations and
Utility Installations (except for Protected Lessee Owned Alterations)
shall, at the expiration or termination of this Lease, unless removed by
Lessee pursuant to this Lease, become the property of Lessor and be
surrendered by Lessee with the Premises.
(b) REMOVAL. By delivery to Lessee of written notice from Lessor
not earlier than ninety (90) and not later than thirty (30) days prior
to the end of the term of this Lease, Lessor may require that any or all
Lessee Owned Alterations or Utility Installations be removed by the
expiration or termination of this Lease. Lessor may require the removal
at any time of all or any part of any Lessee Owned Alterations or
Utility Installations made without the required consent.
(c) SURRENDER/RESTORATION. Lessee shall surrender the Premises
by the Expiration Date or any earlier termination date, with all of the
improvements, parts and surfaces thereof broom clean and free of debris,
and in good operating order, condition and state of repair, ordinary
wear and tear excepted. "Ordinary wear and tear" shall not include any
damage or deterioration that would have been prevented by good
maintenance practice. Lessee shall repair any damage occasioned by the
installation, maintenance or removal of Trade Fixtures, Lessee Owned
Alterations and/or Utility Installations, furnishings, and equipment as
well as the removal of any storage tank installed by or for Lessee, and
the removal, replacement, or remediation of any soil, material or
groundwater contaminated by Lessee. Trade Fixtures shall remain the
property of Lessee and shall be removed by Lessee. The failure by Lessee
to timely vacate the Premises
12
13
pursuant to this Paragraph 7.4(c) without the express written consent of Lessor
shall constitute a holdover under the provisions of Paragraph 26 below.
8. INSURANCE; INDEMNITY.
8.1. PAYMENT FOR INSURANCE.
Lessee shall pay for all insurance required under Paragraph 8 except to
the extent of the cost attributable to liability insurance carried by
Lessor under Paragraph 8.2(b) in excess of $2,000,000 per occurrence.
Premiums for policy periods commencing prior to or extending beyond the
Lease term shall be prorated to correspond to the Lease term. Payment
shall be made by Lessee to Lessor within ten (10) days following receipt
of an invoice.
8.2. LIABILITY INSURANCE.
(a) CARRIED BY LESSEE. Lessee shall obtain and keep in
force a Commercial General Liability Policy of insurance
protecting Lessee and Lessor against claims for bodily injury,
personal injury and property damage based upon or arising out of
the ownership, use, occupancy or maintenance of the Premises and
all areas appurtenant thereto. Such insurance shall be on an
occurrence basis providing single limit coverage in an amount
not less than $2,000,000 per occurrence with an "ADDITIONAL
INSURED-MANAGERS OR LESSORS OF PREMISES ENDORSEMENT" and contain
the "AMENDMENT OF THE POLLUTION EXCLUSION ENDORSEMENT" for
damage caused by heat, smoke or fumes from a hostile fire. The
Policy shall not contain any intra-insured exclusions as between
insured persons or organizations, but shall include coverage for
liability assumed under this Lease as an "insured contract" for
the performance of Lessee's indemnity obligations under this
Lease. The limits of said insurance shall not, however, limit
the liability of Lessee nor relieve Lessee of any obligation
hereunder. All insurance carried by Lessee shall be primary to
and not contributory with any similar insurance carried by
Lessor, whose insurance shall be considered excess insurance
only.
(b) CARRIED BY LESSOR. Lessor shall maintain liability
insurance as described in Paragraph 8.2(a), in addition to, and
not in lieu of, the insurance required to be maintained by
Lessee. Lessee shall not be named as an additional insured
therein.
8.3. PROPERTY INSURANCE - BUILDING, IMPROVEMENTS AND RENTAL VALUE.
(a) BUILDING AND IMPROVEMENTS. The Insuring Party shall obtain
and keep in force a policy or policies in the name of Lessor, with loss
payable to Lessor, any groundlessor, and to any Lender(s) insuring loss
or damage to the Premises. The amount of such insurance shall be equal
to the full replacement cost of the Premises, as the same shall exist
from time to time, or the amount required by any Lenders, but in no
event more than the commercially reasonable and available insurable
value thereof. If Lessor is the Insuring Party, however, Lessee Owned
Alterations and Utility Installations, Trade Fixtures, and Lessee's
personal property shall be insured by Lessee under Paragraph 8.4 rather
than by Lessor. If the coverage is available and commercially
appropriate, such policy or policies shall insure against all risks of
direct physical loss or damage (except the perils of flood and/or
earthquake unless required by a Lender), including coverage for debris
removal and the enforcement of any Applicable Requirements requiring the
upgrading, demolition, reconstruction or replacement of any portion of
the Premises
13
14
as the result of a covered loss. Said policy or policies shall also
contain an agreed valuation provision in lieu of any coinsurance clause,
waiver of subrogation, and inflation guard protection causing an
increase in the annual property insurance coverage amount by a factor of
not less than the adjusted U.S. Department of Labor Consumer Price Index
for All Urban Consumers for the city nearest to where the Premises are
located. If such insurance coverage has a deductible clause, the
deductible amount shall not exceed $10,000 per occurrence, and Lessee
shall be liable for such deductible amount in the event of an insured
Loss.
(b) RENTAL VALUE. The Insuring Party shall obtain and keep in
force a policy or policies in the name of Lessor with loss payable to
Lessor and any Lender, insuring the loss of the full Rent for one (1)
year. Said insurance shall provide that in the event the Lease is
terminated by reason of an inured loss, the period of indemnity for such
coverage shall be extended beyond the date of the completion of repairs
or replacement of the Premises, to provide for one full year's loss of
Rent from the date of any such loss. Said insurance shall contain an
agreed valuation provision in lieu of any coinsurance clause, and the
amount of coverage shall be adjusted annually to reflect the projected
Rent otherwise payable by Lessee, for the next twelve (12) month period.
Lessee shall be liable for any deductible amount in the event of such
loss.
(c) ADJACENT PREMISES. If the Premises are part of a larger
building, or of a group of buildings owned by Lessor which are adjacent
to the Premises, the Lessee shall pay for any increase in the premiums
for the property insurance of such building or buildings if said
increase is caused by Lessees acts, omissions, use or occupancy of the
Premises.
8.4. LESSEE'S PROPERTY/BUSINESS INTERRUPTION INSURANCE.
(a) PROPERTY DAMAGE. Lessee shall obtain and maintain insurance
coverage on all of Lessee's personal property, Trade Fixtures, and
Lessee Owned Alterations and Utility Installations. Such insurance shall
be full replacement cost coverage with a deductible of not to exceed
$5,000 per occurrence. The proceeds from any such insurance shall be
used by Lessee for the replacement of personal property, Trade Fixtures
and Lessee Owned Alterations and Utility Installations. Lessee shall
provide Lessor with written evidence that such insurance is in force.
(b) BUSINESS INTERRUPTION. Lessee shall obtain and maintain loss
of income and extra expense insurance in amounts as will reimburse
Lessee for direct or indirect loss of earnings attributable to all
perils commonly insured against by prudent lessees in the business of
Lessee or attributable to prevention of access to the Premises as a
result of such perils.
(c) NO REPRESENTATION OF ADEQUATE COVERAGE. Lessor makes no
representation that the limits or forms of coverage of insurance
specified herein are adequate to cover Lessee's property, business
operations or obligations under this Lease.
8.5. INSURANCE POLICIES.
Insurance required herein shall be by companies duly licensed or
admitted to transact business in the state where the Premises are
located, and maintaining during the policy term a "General Policyholders
Rating" of at least B+, V, as set forth in the most current issue of
"Best's Insurance Guide", or such other rating as may be required by a
Lender. Lessee shall not do or permit to be done anything which
invalidates the required insurance policies. Lessee shall, prior to the
Early Possession Date, deliver to Lessor certified copies of policies of
such insurance or certificates evidencing the existence and amounts of
the required insurance. No
14
15
such policy shall be cancelable or subject to modification except after
thirty (30) days prior written notice to Lessor. Lessee shall, at least
thirty (30) days prior to the expiration of such policies, furnish
Lessor with evidence of renewals or "insurance binders" evidencing
renewal thereof, or Lessor may order such insurance and charge the cost
thereof to Lessee, which amount shall be payable by Lessee to Lessor
upon demand. Such policies shall be for a term of at least one year, or
the length of the remaining term of this Lease, whichever is less. If
either Party shall fail to procure and maintain the insurance required
to be carried by it, the other Party may, but shall not be required to,
procure and maintain the same.
8.6. WAIVER OF SUBROGATION.
Without affecting any other rights or remedies, Lessee and Lessor each
hereby release and relieve the other, and waive their entire right to
recover damages against the other, for loss of or damage to its property
arising out of or incident to the perils required to be insured against
herein. The effect of such releases and waivers is not limited by the
amount of insurance carried or required, or by any deductibles
applicable hereto. The Parties agree to have their respective property
damage insurance carriers waive any right to subrogation that such
companies may have against Lessor or Lessee, as the case may be, so long
as the insurance is not invalidated thereby.
8.7. INDEMNITY.
Except for Lessor's gross negligence or willful misconduct, Lessee shall
indemnify, protect, defend and hold harmless the Premises, Lessor and
its agents, Lessor's master or ground lessor, partners and Lenders, from
and against any and all claims, loss of rents and/or damages, liens,
judgments, penalties, attorneys' and consultants' fees, expenses and/or
liabilities arising out of, involving, or in connection with, the use
and/or occupancy of the Premises by Lessee. If any action or proceeding
is brought against Lessor by reason of any of the foregoing matters,
Lessee shall upon notice defend the same at Lessee's expense by counsel
reasonably satisfactory to Lessor and Lessor shall cooperate with Lessee
in such defense. Lessor need not have first paid any such claim in order
to be defended or indemnified.
8.8. EXEMPTION OF LESSOR FROM LIABILITY.
Subject to the provisions of Section 6 of the Work Letter, Lessor shall
not be liable for injury or damage to the person or goods, wares,
merchandise or other property of Lessee, Lessee's employees,
contractors, invitees, customers, or any other person in or about the
Premises, whether such damage or injury is caused by or results from
fire, steam, electricity, gas, water or rain, or from the breakage,
leakage, obstruction or other defects of pipes, fire sprinklers, wires,
appliances, plumbing, HVAC or lighting fixtures, or from any other
cause, whether the said injury or damage results from conditions arising
upon the Premises or upon other portions of the Building of which the
Premises are a part, or from other sources or places. Lessor shall not
be liable for any damages arising from any act or neglect of any other
tenant of Lessor. Notwithstanding Lessor's negligence or breach of this
Lease, Lessor shall under no
15
16
circumstances be liable for injury to Lessee's business or for any loss
of income or profit therefrom.
9. DAMAGE OR DESTRUCTION.
9.1. DEFINITIONS.
(a) "PREMISES PARTIAL DAMAGE" shall mean damage or destruction
to the improvements on the Premises, other than Lessee Owned Alterations
and Utility Installations, which can reasonably be repaired in six (6)
months or less from the date of the damage or destruction. Lessor shall
notify Lessee in writing within thirty (30) days from the date of the
damage or destruction as to whether or not the damage is Partial or
Total.
(b) "PREMISES TOTAL DESTRUCTION" See Addendum Paragraph 53
(c) "INSURED LOSS" shall mean damage or destruction to
improvements on the Premises' other than Lessee Owned Alterations and
Utility Installations and Trade Fixtures, which was caused by an event
required to be covered by the insurance described in Paragraph 8.3(a),
irrespective of any deductible amounts or coverage limits involved.
(d) "REPLACEMENT COST" shall mean the cost to repair or rebuild
the improvements owned by Lessor at the time of the occurrence to their
condition existing immediately prior thereto, including demolition,
debris removal and upgrading required by the operation of Applicable
Requirements, and without deduction for depreciation.
(e) "HAZARDOUS SUBSTANCE CONDITION" shall mean the occurrence or
discovery of a condition involving the presence of, or a contamination
by, a Hazardous Substance as defined in Paragraph 6.2(a), in, on, or
under the Premises.
9.2. PARTIAL DAMAGE - INSURED LOSS.
If a Premises Partial Damage that is an Insured Loss occurs, then Lessor
shall, at Lessor's expense, repair such damage (but not Lessee's Trade
Fixtures or Lessee Owned Alterations and Utility Installations) as soon
as reasonably possible and this Lease shall continue in full force and
effect; provided, however, that Lessee shall, at Lessor's election, make
the repair of any damage or destruction the total cost to repair of
which is $10,000 or less, and, in such event, Lessor shall make any
applicable insurance proceeds available to Lessee on a reasonable basis
for that purpose. Notwithstanding the foregoing, if the required
insurance was not in force or the insurance proceeds are not sufficient
to effect such repair, the Insuring Party shall promptly contribute the
shortage in proceeds (except as to the deductible which is Lessee's
responsibility) as and when required to complete said repairs. In the
event, however, such shortage was due to the fact that, by reason of the
unique nature of the improvements, full replacement cost insurance
coverage was not commercially reasonable and available, Lessor shall
have no obligation to pay for the shortage in insurance proceeds or to
fully restore the unique aspects of the Premises unless Lessee provides
Lessor with the funds to cover same, or adequate assurance thereof,
within ten (10) days following receipt of written notice of such
shortage and request therefor. If Lessor receives said funds or adequate
assurance thereof within said ten (10) day period, the party
responsible for making the repairs shall complete them as soon as
reasonably possible and this Lease shall remain in full force and
effect. If such funds or assurance are not received, Lessor may
nevertheless elect by
16
17
written notice to Lessee within ten (10) days thereafter to: (i) make
such restoration and repair a is commercially reasonable with Lessor
paying any shortage in proceeds, in which case this Lease shall remain
in full force and effect, or (ii) have this Lease terminate thirty (30)
days thereafter. Lessee shall not be entitled to reimbursement of any
funds contributed by Lessee to repair any such damage or destruction.
Premises Partial Damage due to flood or earthquake shall be subject to
Paragraph 9.3, notwithstanding that there may be some insurance
coverage, but the net proceeds of any such insurance shall be made
available for the repairs if made by either Party.
9.3. PARTIAL DAMAGE - UNINSURED LOSS.
If a Premises Partial Damage that is not an Insured Loss occurs, unless
caused by a negligent or willful act of Lessee (in which event Lessee
shall make the repairs at Lessee's expense), Lessor may either: (i)
repair such damage as soon as reasonably possible at Lessor's expense,
in which event this Lease shall continue in full force and effect, or
(ii) terminate this Lease by giving written notice to Lessee within
thirty (30) days after receipt by Lessor of knowledge of be occurrence
of such damage. Such termination shall be effective sixty (60) days
following the date of such notice. In the event Lessor elects to
terminate this Lease, Lessee shall have the right within ten (10) days
after receipt of the termination notice to give written notice to Lessor
of Lessee's commitment to pay for the repair of such damage without
reimbursement from Lessor. Lessee shall provide Lessor with said funds
or satisfactory assurance thereof within thirty (30) days after making
such commitment. In such event this Lease shall continue in full force
and effect, and Lessor shall proceed to make such repairs as soon as
reasonably possible after the required funds are available. If Lessee
does not make the required commitment, this Lease shall terminate as of
the date specified in the termination notice. (See Addendum Paragraph
54)
9.4. TOTAL DESTRUCTION.
Notwithstanding any other provision hereof, if a Premises Total
Destruction occurs, this Lease shall terminate sixty (60) days
following such Destruction. If the damage or destruction was caused by
the gross negligence or willful misconduct of Lessee, Lessor shall have
the right to recover Lessor's damages from Lessee, except as provided in
Paragraph 8.6.
9.5. DAMAGE NEAR END OF TERM.
If at any time during the last six (6) months of this Lease there is
damage for which the cost to repair exceeds one (1) month's Base Rent,
whether or not an Insured Loss, Lessor may terminate this Lease
effective sixty (60) days following the date of occurrence of such
damage by giving a written termination notice to Lessee within thirty
(30) days after the date of occurrence of such damage. Notwithstanding
the foregoing, if Lessee at that time has an exercisable option to
extend this Lease or to purchase the Premises, then Lessee may preserve
this Lease by, (a) exercising such option and (b) subject to Lessor's
obligation under Paragraph 9.3 as revised, providing Lessor with any
shortage in insurance proceeds (or adequate assurance thereof) needed to
make there pairs on or before the earlier of (i) the date which is ten
days after Lessee's receipt of Lessor written notice purporting to
terminate this Lease, or (ii) the day prior to the date upon which such
option expires. If Lessee duly exercises such option during such period
and provides
17
18
Lessor with funds (or adequate assurance thereof to cover any shortage
in insurance proceeds), Lessor shall, at Lessor's commercially
reasonable expense, repair such damage as soon as reasonably possible
and this Lease shall continue in full force and effect. If Lessee fails
to exercise such option and provide such funds or assurance during such
period, then this Lease shall terminate on the date specified in the
termination notice and Lessee's option shall be extinguished. (See
Addendum Paragraph 55)
9.6. ABATEMENT OF RENT; LESSEE'S REMEDIES.
(a) ABATEMENT. In the event of Premises Partial Damage or
Premises Total Destruction or a Hazardous Substance Condition for which
Lessee is not responsible under this Lease, the Rent payable by Lessee
for the period required for the repair, remediation or restoration of
such damage shall be abated in proportion to the degree to which
Lessee's use of the Premises is impaired, but not to exceed the proceeds
received from the Rental Value insurance. All other obligations of
Lessee hereunder shall be performed by Lessee, and Lessor shall have no
liability for any such damage, destruction, remediation, repair or
restoration except as provided herein.
(b) REMEDIES. If Lessor shall be obligated to repair or restore
the Premises and does not commence, in a substantial and meaningful way,
such repair or restoration within ninety (90) days after such obligation
shall accrue, Lessee may, at any time prior to the commencement of such
repair or restoration, give written notice to Lessor and to any Lenders
of which Lessee has actual notice, of Lessee's election to terminate
this Lease on a date not less than sixty (60) days following the giving
of such notice. If Lessee gives such notice and such repair or
restoration is not commenced within thirty (30) days thereafter, this
Lease shall terminate as of the date specified in said notice. If the
repair or restoration is commenced within said thirty (30) days, this
Lease shall continue in full force and effect. "COMMENCE" shall mean
either the unconditional authorization of the preparation of the
required plans, or the beginning of the actual work on the Premises,
whichever first occurs.
9.7. TERMINATION - ADVANCE PAYMENTS.
Upon termination of this Lease pursuant to Paragraph 6.2(g) or Paragraph
9, an equitable adjustment shall be made concerning advance Base Rent
and any other advance payments made by Lessee to Lessor. Lessor shall,
in addition, return to Lessee so much of Lessee's Security Deposit as
has not been, or is not then required to be, used by Lessor.
9.8. WAIVE STATUTES.
Lessor and Lessee agree that the terms of this Lease shall govern the
effect of any damage to or destruction of the Premises with respect to
the termination of this Lease and hereby waive the provisions of any
present or future statute to the extent inconsistent herewith.
10. REAL PROPERTY TAXES.
10.1. DEFINITION OF "REAL PROPERTY TAXES."
As used herein, the term "REAL PROPERTY TAXES" shall include any form of
assessment; real estate, general, special, ordinary or extraordinary or
ad valorem real estate taxes and assessments (other than inheritance,
personal income or estate taxes); and/or improvement bond imposed upon
or levied against any legal or equitable interest of Lessor in the
Premises,
18
19
by any authority having the direct or indirect power to tax and where
the funds are generated with reference to the Building address and where
the proceeds so generated are to be applied by the city, county or other
local taxing authority of a jurisdiction within which the Premises are
located. The term "REAL PROPERTY TAXES" shall also include any tax, fee,
levy, assessment or charge, or any increase therein, imposed by reason
of events occurring during the term of this Lease, including but not
limited to, a change in the ownership of the Premises.
10.2.
(a) PAYMENT OF TAXES. Lessee shall pay the Real Property Taxes
applicable to the Premises during the term of this Lease. Subject to
Paragraph 10.2(b), all such payments shall be made at least ten (10)
days prior to any delinquency date. Lessee shall promptly furnish Lessor
with satisfactory evidence that such taxes have been paid. If any such
taxes shall cover any period of time prior to or after the expiration or
termination of this Lease, Lessee's share of such taxes shall be
prorated to cover only that portion of the tax xxxx applicable to the
period that this Lease is in effect, and Lessor shall reimburse Lessee
for any overpayment. if Lessee shall fail to pay any required Real
Property Taxes, Lessor shall have the right to pay the same, and Lessee
shall reimburse Lessor therefor upon demand.
(b) ADVANCE PAYMENT. In the event Lessee incurs a late charge on
any Rent payment, Lessor may, at Lessor's option, estimate the current
Real Property Taxes, and require that such taxes be paid in advance to
Lessor by Lessee, either: (i) in a lump sum amount equal to the
installment due, at least twenty (20) days prior to the applicable
delinquency date, or (ii) monthly in advance with the payment of the
Base Rent. If Lessor elects to require payment monthly in advance, the
monthly payment shall be an amount equal to the amount of the estimated
installment of taxes divided by the number of months remaining before
the month in which said installment becomes delinquent. When the actual
amount of the applicable tax xxxx is known, the amount of such equal
monthly advance payments shall be adjusted as required to provide the
funds needed to pay the applicable taxes. If the amount collected by
Lessor is insufficient to pay such Real Property Taxes when due, Lessee
shall pay Lessor, upon demand, such additional sums as are necessary to
pay such obligations. All monies paid to Lessor under this Paragraph may
be intermingled with other monies of Lessor and shall not bear interest.
In the event of a Breach by Lessee in the performance of its obligations
under this Lease, then any balance of funds paid to Lessor under the
provisions of this Paragraph may, at the option of Lessor, be treated as
an additional Security Deposit.
10.3. JOINT ASSESSMENT.
If the Premises are not separately assessed, Lessee's liability shall be
an equitable proportion of the Real Property Taxes for all of the land
and improvements included within the tax parcel assessed, such
proportion to be conclusively determined by Lessor from the respective
valuations assigned in the assessor's work sheets or such other
information as may be reasonably available.
10.4. PERSONAL PROPERTY TAXES.
Lessee shall pay, prior to delinquency, all taxes assessed against and
levied upon Lessee Owned Alterations, Utility Installations, Trade
Fixtures, furnishings, equipment and all personal property
19
20
of Lessee. When possible, Lessee shall cause such property to be
assessed and billed separately from the real property of Lessor. If any
of Lessee's said personal property shall be assessed with Lessor's real
property, Lessee shall pay Lessor the taxes attributable to Lessee's
property within ten (10) days after receipt of a written statement.
11. UTILITIES.
Lessee shall pay for all water, gas, heat, light, power, telephone,
trash disposal and other utilities and services supplied to the
Premises, together with any taxes thereon. If any such services are not
separately metered to Lessee, Lessee shall pay a reasonable proportion,
to be determined by Lessor, of all charges jointly metered.
12. ASSIGNMENT AND SUBLETTING.
12.1. LESSOR'S CONSENT REQUIRED.
(a) Lessee shall not voluntarily or by operation of law assign,
transfer, mortgage or encumber (collectively, "ASSIGN OR ASSIGNMENT")
or sublet all or any part of Lessee's interest in this Lease or in the
Premises without Lessor's prior written consent which consent shall be
deemed granted unless Lessor has refused its consent by notice to Lessee
given within twenty (20) days following notice from Lessee requesting
such consent and which consent shall not be unreasonably withheld or
delayed.
(b) See Addendum Paragraph 56
(c) The involvement of Lessee or its assets in any transaction,
or series of transactions (by way of merger, sale, acquisition,
financing, transfer, leveraged buy-out or otherwise), whether or not a
formal assignment or hypothecation of this Lease or Lessee's assets
occurs, which results or will result in a reduction of the Net Worth of
Lessee by an amount greater than twenty-five percent (25%) of such Net
Worth as it was represented at the time of the execution of this Lease
or at the time of the most recent assignment to which Lessor has
consented, or as it exists immediately prior to said transaction or
transactions constituting such reduction, whichever was or is greater,
shall be considered an assignment of this Lease to which Lessor may
withhold its consent. "NET WORTH OF LESSEE" shall mean the net worth of
Lessee (excluding any guarantors) established under generally accepted
accounting principles.
(d) An assignment or subletting without consent shall, at
Lessor's option, be a Default curable after notice per Paragraph 13.1
(c), or a noncurable Breach without the necessity of any notice and
grace period. If Lessor elects to treat such unapproved assignment or
subletting as a noncurable Breach, Lessor may either: (i) terminate this
Lease, or (ii) upon thirty (30) days written notice, increase the
monthly Base Rent to one hundred ten percent (110%) of the Base Rent
then in effect. Further, in the event of such Breach and rental
adjustment, (i) the purchase price of any option to purchase the
Premises held by Lessee shall be subject to similar adjustment to one
hundred ten percent (110%) of the price previously in effect, and (ii)
all fixed and non-fixed rental adjustments scheduled during the
remainder of the Lease term shall be increased to One Hundred Ten
Percent (110%) of the scheduled adjusted rent.
12.2. TERMS AND CONDITIONS APPLICABLE TO ASSIGNMENT AND SUBLETTING.
(a) Regardless of Lessors consent, any assignment or subletting
shall not: (i) be effective without the express written assumption by
such assignee or sublessee of the obligations of
20
21
Lessee under this Lease; (ii) release Lessee of any obligations
hereunder; or (iii) alter the primary liability of Lessee for the
payment of Rent or for the performance of any other obligations to be
performed by Lessee.
(b) Lessor may accept Rent or performance of Lessee's
obligations from any person other than Lessee pending approval or
disapproval of an assignment. The acceptance of Rent or performance
shall not constitute a waiver or estoppel of Lessor's right to exercise
its remedies for Lessee's Default or Breach.
(c) Lessor's consent to any assignment or subletting shall not
constitute a consent to any subsequent assignment or subletting.
(d) In the event of any Default or Breach by Lessee, Lessor may
proceed directly against Lessee, any Guarantors or anyone else
responsible for the performance of Lessee's obligations under this
Lease, including any assignee or sublessee, without first exhausting
Lessor's remedies against any other person or entity responsible
therefore to Lessor, or any security held by Lessor.
(e) Each request for consent to an assignment or subletting
shall be in writing, accompanied by information relevant to Lessor's
determination as to the financial and operational responsibility and
appropriateness of the proposed assignee or sublessee, including but not
limited to the intended use and/or required modification of the
Premises, if any, together with a fee of $ 1,000, as consideration for
Lessor's considering and processing said request. Lessee agrees to
provide Lessor with such other or additional information and/or
documentation as may be reasonably requested.
(f) Any assignee of, or sublessee under, this Lease shall, by
reason of accepting such assignment or entering into such sublease, be
deemed to have assumed and agreed to conform and comply with each and
every term in, covenant, condition and obligation herein to be observed
or performed by Lessee during the term of said assignment or sublease,
other than such obligations as are contrary to or inconsistent with
provisions of an assignment or sublease to which Lessor has specifically
consented to in writing.
12.3. ADDITIONAL TERMS AND CONDITIONS APPLICABLE TO SUBLETTING.
The following terms and conditions shall apply to any subletting by
Lessee of all or any part of the Premises and shall be deemed included
in all subleases under this Lease whether or not expressly incorporated
therein:
(a) Lessee hereby assigns and transfers to Lessor all of
Lessee's interest in all Rent payable on any sublease, and Lessor may
collect such Rent and apply same toward Lessee's obligations under this
Lease; provided, however, that until a Breach shall occur in the
performance of Lessee's obligations, Lessee may collect said Rent.
Lessor shall not, by reason of the foregoing or any assignment of such
sublease, nor by reason of the collection of Rent, be deemed liable to
the sublessee for any failure of Lessee to perform and comply with any
of Lessee's obligations to such sublessee. Lessee hereby irrevocably
authorizes and directs any such sublessee, upon receipt of a written
notice from Lessor stating that a Breach exists in the performance of
Lessee's obligations under this Lease, to pay to Lessor all Rent due and
to become due under the sublease, Sublessee shall rely upon any such
notice from Lessor and shall pay all Rents to Lessor without any
obligation or right to inquire as to whether such Breach exists,
notwithstanding any claim from Lessee to the contrary. Any sublease rent
in excess of the Rent and other payments due to Lessor from Lessee
hereunder shall belong to Lessee.
21
22
(b) In the event of a Breach by Lessee, Lessor may, at its
option, require sublessee to attorn to Lessor, in which event Lessor
shall undertake the obligations of the sublessor under such sublease
from the time of the exercise of said option to the expiration of such
sublease; provided, however, Lessor shall not be liable for any prepaid
rents or security deposit paid by such sublessee to such sublessor or
for any prior Defaults or Breaches of such sublessor.
(c) Any matter requiring the consent of the sublessor under a
sublease shall also require the consent of Lessor.
(d) No sublessee shall further assign or sublet all or any part
of the Premises without Lessor's prior written consent.
(e) Lessor shall deliver a copy of any notice of Default or
Breach by Lessee to the sublessee, who shall have the right to cure the
Default of Lessee within the grace period, if any, specified in such
notice. The sublessee shall have a right of reimbursement and offset
from and against Lessee for any such Defaults cured by the sublessee.
13. DEFAULT; BREACH; REMEDIES.
13.1. DEFAULT; BREACH.
A "DEFAULT" is defined as a failure by the Lessee to comply with
or perform any of the terms, covenants, conditions or rules
under this Lease. A "BREACH" is defined as the occurrence of one
or more of the following Defaults, and the failure of Lessee to
cure such Default within any applicable grace period:
(a) The abandonment of the Premises; or the vacating of the
Premises without providing a commercially reasonable level of security,
or where the coverage of the property insurance described in Paragraph
8.3 is jeopardized as a result thereof, or without providing reasonable
assurances to minimize potential vandalism.
(b) The failure of Lessee to make any payment of Rent or any
Security Deposit required to be made by Lessee hereunder, whether to
Lessor or to a third party, when due, to provide reasonable evidence of
insurance or surety bond, or to fulfill any obligation under this Lease
which endangers or threatens life or property, where such failure
continues for a period of three (3) business days following written
notice to Lessee.
(c) The failure by Lessee to provide (i) reasonable written
evidence of compliance with Applicable Requirements, (ii) the service
contracts, (iii) the rescission of an unauthorized assignment or
subletting, (iv) a Tenancy Statement, (v) a requested subordination,
(vi) evidence concerning any guaranty and/or Guarantor, (vii) any
document requested under Paragraph 42 (easements), or (viii) any other
documentation or information which Lessor may reasonably require of
Lessee under the terms of this Lease, where any such failure continues
for a period of ten (10) days following written notice to Lessee.
(d) A Default by Lessee as to the terms, covenants, conditions
or provisions of this Lease, or of the rules adopted under Paragraph 40
hereof, other than those described in subparagraphs 13.1 (a), (b) or
(c), above, where such Default continues for a period of thirty (30)
days after written notice; provided, however, that if the nature of
Lessee's Default is such that more than thirty (30) days are reasonably
required for its cure, then it shall not be deemed to be a Breach if
Lessee commences such cure within said thirty (30) day period and
thereafter diligently prosecutes such cure to completion.
22
23
(e) The occurrence of any of the following events: (i) the
making of any general arrangement or assignment for the benefit of
creditors; (ii) becoming a "debtor" as defined in 11 U.S.C. Section 101
or any successor statute thereto (unless, in the case of a petition
filed against Lessee, the same is dismissed within sixty (60) days);
(iii) the appointment of a trustee or receiver to take possession of
substantially all of Lessee's assets located at the Premises or of
Lessee's interest in this Lease, where possession is not restored to
Lessee within thirty (30) days; or (iv) the attachment, execution or
other judicial seizure of substantially all of Lessee's assets located
at the Premises or of Lessee's interest in this Lease, where such
seizure is not discharged within thirty (30) days; provided, however, in
the event that any provision of this subparagraph 13.1 (e) is contrary
to any applicable law, such provision shall be of no force or effect,
and not affect the validity of the remaining provisions.
(f) The discovery that any financial statement of Lessee or of
any Guarantor given to Lessor was materially false.
(g) If the performance of Lessee's obligations under this Lease
is guaranteed: (i) the death of a Guarantor; (ii) the termination of a
Guarantor's liability with respect to this Lease other than in
accordance with the terms of such guaranty; (iii) a Guarantor's becoming
insolvent or the subject of a bankruptcy filing; (iv) a Guarantor's
refusal to honor the guaranty; or (v) a Guarantor's breach of its
guaranty obligation on an anticipatory basis, and Lessee's failure,
within sixty (60) days following written notice of any such event, to
provide written alternative assurance or security, which, when coupled
with the then existing resources of Lessee, equals or exceeds the
combined financial resources of Lessee and the Guarantors that existed
at the time of execution of this Lease.
13.2. REMEDIES.
If Lessee fails to perform any of its affirmative duties or
obligations, within ten (10) days after written notice (or in
case of any emergency, without notice), Lessor may, at its
option, perform such duty or obligation on Lessee's behalf,
including but not limited to the obtaining of reasonably
required bonds, insurance policies, or governmental licenses,
permits or approvals. The costs and expenses of any such
performance by Lessor shall be due and payable by Lessee upon
receipt of invoice therefor. In the event of a Breach, Lessor
may, with or without further notice or demand, and without
limiting Lessor in the exercise of any right or remedy which
Lessor may have by reason of such Breach:
(a) Terminate Lessee's right to possession of the Premises by
any lawful means, in which case this Lease shall terminate and Lessee
shall immediately surrender possession to Lessor. In such event Lessor
shall be entitled to recover from Lessee: (i) the unpaid Rent which had
been earned at the time of termination; (ii) the worth at the time of
award of the amount by which the unpaid rent which would have been
earned after termination until the time of award exceeds the amount of
such rental loss that the Lessee proves could have been reasonably
avoided; (iii) the worth at the time of award of the amount by which the
unpaid rent for the balance of the term after the time of award exceeds
the amount of such rental loss that the Lessee proves could be
reasonably avoided; and (iv) any other amount necessary to compensate
Lessor for all the detriment proximately caused by the Lessee's failure
to perform its obligations under this Lease or which in the ordinary
course of things would be likely to result therefrom, including but not
limited to the cost of recovering possession of the Premises, expenses
of relating, including
23
24
necessary renovation and alteration of the Premises, reasonable
attorneys' fees, and that portion of any leasing commission paid by
Lessor in connection with this Lease applicable to the unexpired term of
this Lease. The worth at the time of award of the amount referred to in
provision (iii) of the immediately preceding sentence shall be computed
by discounting such amount at the discount rate of the Federal Reserve
Bank of the District within which the Premises are located at the time
of award plus one percent (1%). Efforts by Lessor to mitigate damages
caused by Lessee's Breach of this Lease shall not waive Lessor's right
to recover the balance of damages owing under Paragraph 12. If
termination of this Lease is obtained through the provisional remedy of
unlawful detainer, Lessor shall have the right to recover in such
proceeding any unpaid Rent and damages as are recoverable therein, or
Lessor may reserve the right to recover all or any part thereof in a
separate suit. If the notice and grace period required under Paragraph
13.1 was not previously given, a notice to pay rent or quit, or to
perform or quit given to Lessee under the unlawful detainer statute
shall also constitute the notice required by Paragraph 13.1. In such
case, the applicable grace period required by Paragraph 13.1 and the
unlawful detainer statute shall run concurrently, and the failure of
Lessee to cure the Default within the greater of the two such grace
periods shall constitute both an unlawful detainer and a Breach of this
Lease entitling Lessor to the remedies provided for in this Lease and/or
by said statute.
(b) Continue the Lease and Lessee's right to possession and
recover the Rent as it becomes due, in which event Lessee may sublet or
assign, subject only to reasonable limitations. Acts of maintenance,
efforts to relet, and/or the appointment of a receiver to protect the
Lessor's interests, shall not constitute a termination of the Lessee's
right to possession.
(c) Pursue any other remedy now or hereafter available under the
laws or judicial decisions of the state wherein the Premises are
located. The expiration or termination of this Lease and/or the
termination of Lessee's right to possession shall not relieve Lessee
from liability under any indemnity provisions of this Lease as to
matters occurring or accruing during the term hereof or by reason of
Lessee's occupancy of the Premises.
(d) If the nature of Lessee's obligation is such that more than
thirty (30) days are reasonably required for its performance, then
Lessee, shall not be in breach if performance is commenced within such
thirty (30) day period and thereafter diligently pursued to completion.
13.3. INDUCEMENT RECAPTURE.
Intentionally Omitted
13.4. LATE CHARGES.
Lessee hereby acknowledges that late payment by Lessee of Rent
will cause Lessor to incur costs not contemplated by this Lease,
the exact amount of which will be extremely difficult to
ascertain. Such costs include, but are not limited to,
processing and accounting charges, and late charges which may be
imposed upon Lessor by any Lender. Accordingly, if any Rent
shall not be received by Lessor within five (5) days after such
amount shall be due, then, without any requirement for notice to
Lessee, Lessee shall pay to Lessor a one-time late charge equal
to three percent (3%) of each such overdue amount. The Parties
hereby agree that such late charge represents a fair and
reasonable estimate of the costs Lessor will incur by
24
25
reason of such late payment. Acceptance of such late charge by Lessor
shall in no event constitute a waiver of Lessee's Default or Breach with
respect to such overdue amount nor prevent the exercise of any of the
other rights and remedies granted hereunder. In the event that a late
charge is payable hereunder, whether or not collected, for three (3)
consecutive installments of Base Rent, then notwithstanding any
provision of this Lease to the contrary, Base Rent shall, at Lessor's
option, become due and payable quarterly in advance.
13.5. INTEREST.
Any monetary payment due Lessor hereunder, other than late charges and
Rent received by Lessor within five (5) days after such amount shall be
due, not received by Lessor, when due as to scheduled payments (such as
Base Rent) or within thirty (30) days following the date on which it was
due for non-scheduled payment, shall bear interest from the date when
due, as to scheduled payments, or the thirty-first (31st) day after it
was due as to non-scheduled payments. The interest ("Interest") charged
shall be equal to the prime rate reported in the Wall Street Journal as
published closest prior to the date when due plus four percent (4%), but
shall not exceed the maximum rate allowed by law. Interest is payable in
addition to the potential late charge provided for in Paragraph 13.4.
13.6. BREACH BY LESSOR.
(a) NOTICE OF BREACH. Lessor shall not be deemed in breach of
this Lease unless Lessor fails within a reasonable time to perform an obligation
required to be performed by Lessor. For purposes of this Paragraph, a reasonable
time shall in no event be less than thirty (30) days after receipt by Lessor,
and any Lender whose name and address shall have been furnished Lessee in
writing for such purpose, of written notice specifying wherein such obligation
of Lessor has not been performed; provided, however, that if the nature of
Lessor's obligation is such that more than thirty (30) days are reasonably
required for its performance, then Lessor shall not be in breach if performance
is commenced within such thirty (30) day period and thereafter diligently
pursued to completion.
(b) PERFORMANCE BY LESSEE ON BEHALF OF LESSOR. In the event that
neither Lessor nor Lender cures said breach within thirty (30) days after
receipt of said notice, or if having commenced said cure they do not diligently
pursue it to completion, then Lessee may elect to cure said breach at Lessee's
expense and offset from Rent an amount equal to the greater of one month's Base
Rent or the Security Deposit, and to pay an excess of such expense under
protest, reserving Lessee's right to reimbursement from Lessor. Lessee shall
document the cost of said cure and supply said documentation to Lessor.
14. CONDEMNATION.
If the Premises or any portion thereof are taken under the power of eminent
domain or sold under the threat of the exercise of said power (collectively
"CONDEMNATION"), this Lease shall terminate as to the part taken as of the date
the condemning authority takes title or possession, whichever first occurs. If
more than ten percent (10%) of any building portion of the Premises, or more
than twenty-five percent (25%) of the land area portion of the Premises not
occupied by any building, is taken by Condemnation, Lessee may, at Lessee's
option, to be exercised in writing within ten (10) days after Lessor shall have
given Lessee written notice of such taking (or
25
26
in the absence of such notice, within ten (10) days after the condemning
authority shall have taken possession) terminate this Lease as of the date the
condemning authority takes such possession. If Lessee does not terminate this
Lease in accordance with the foregoing, this Lease shall remain in full force
and effect as to the portion of the Premises remaining, except that the Base
Rent shall be reduced in proportion to the reduction in utility of the Premises
caused by such Condemnation. See Addendum Paragraph 57. All Alterations and
Utility Installations made to the Premises by Lessee, for purposes of
Condemnation only, shall be considered the property of the Lessee and Lessee
shall be entitled to any and all compensation which is payable therefor. In the
event that this Lease is not terminated by reason of the Condemnation, Lessor
shall repair any damage to the Premises caused by such Condemnation.
15. BROKERS' FEE.
15.1.
[Intentionally omitted]
15.2. ASSUMPTION OF OBLIGATIONS.
[Intentionally omitted]
15.3. REPRESENTATIONS AND INDEMNITIES OF BROKER RELATIONSHIPS.
Lessee and Lessor each represent and warrant to the other that it has
had no dealings with any person, firm, broker or finder (other than the
Brokers, if any) in connection with this Lease, and that no one other
than said named Brokers it, entitled to any commission or finder's fee
in connection herewith. Lessee and Lessor do each hereby agree to
indemnify, protect, defend and hold the other harmless from and against
liability for compensation or charges which may be claimed by any such
unnamed broker, finder or other similar party by reason of any dealings
or actions of the Indemnifying Party, including any costs, expenses,
and/or attorneys' fees reasonably incurred with respect thereto.
16. ESTOPPEL CERTIFICATES.
(a) Each Party (as "RESPONDING PARTY") shall within ten (10)
days after written notice from the other Party (the "REQUESTING PARTY")
execute, acknowledge and deliver to the Requesting Party a statement in
writing in form similar to the then most current "ESTOPPEL CERTIFICATE"
form published by the American Industrial Real Estate Association, plus
such additional information, confirmation and/or statements as may be
reasonably requested by the Requesting Party.
(b) If the Responding Party shall fail to execute or deliver the
Estoppel Certificate within such ten day period, the Requesting Party
may execute an Estoppel Certificate stating that: (i) the Lease is in
full force and effect without modification except as may be represented
by the Requesting Party, (ii) there are no uncured defaults in the
Requesting Party's performance, and (iii) if Lessor is the Requesting
Party, not more than one month's Rent has been paid in advance.
Prospective purchasers and encumbrancers may rely upon the Requesting
Party's Estoppel
26
27
Certificate, and the Responding Party shall be estopped from denying the
truth of the facts contained in said Certificate.
(c) If Lessor desires to finance, refinance, or sell the
Premises, or any part thereof, Lessee and all Guarantors shall deliver
to any potential lender or purchaser designated by Lessor such financial
statements as may be reasonably required by such lender or purchaser,
including, but not limited to, Lessees financial statements for the past
three (3) years. All such financial statements shall be received by
Lessor and such lender or purchaser in confidence and shall be used only
for the purposes herein set forth.
17. DEFINITION OF LESSOR.
The term "Lessor" as used herein shall mean the owner or owners at the time in
question of the fee title to the Premises, or, if this is a sublease, of the
Lessee's interest in the prior lease. In the event of a transfer of Lessor's
title or interest in the Premises or this Lease, Lessor shall deliver to the
transferee or assignee (in cash or by credit) any unused Security Deposit held
by Lessor. Except as provided in Paragraph 15, upon such transfer or assignment
and delivery of the Security Deposit, as aforesaid, the prior Lessor shall be
relieved of all liability with respect to the obligations and/or covenants under
this Lease thereafter to be performed by the Lessor. Subject to the foregoing,
the obligations and/or covenants in this Lease to be performed by the Lessor
shall be binding only upon the Lessor as hereinabove defined. Notwithstanding
the above, and subject to the provisions of Paragraph 20 below, the original
Lessor under this Lease, and all subsequent holders of the Lessor's interest in
this Lease shall remain liable and responsible with regard to the potential
duties and liabilities of Lessor pertaining to Hazardous Substances as outlined
in Paragraph 6 above.
18. SEVERABILITY.
The invalidity of any provision of this Lease, as determined by a court of
competent jurisdiction, shall in no way affect the validity of any other
provision hereof.
19. DAYS.
Unless otherwise specifically indicated to the contrary, the word "days" as used
in this Lease shall mean and refer to calendar days.
20. LIMITATION ON LIABILITY.
Subject to the provisions of Paragraph 17 above, the obligations of Lessor under
this Lease shall not constitute personal obligations of the individual partners
of Lessor or its or their individual, partners, directors, officers or
shareholders, and Lessee shall look to the Premises, and to no other assets of
Lessor, for the satisfaction of any liability of Lessor with respect to this
Lease, and shall not seek recourse against the individual partners of Lessor, or
its or their individual partners, directors, officers or shareholders, or any of
their personal assets for such satisfaction.
21. TIME OF ESSENCE.
Time is of the essence with respect to the performance of all obligations to be
performed or observed by the Parties under this Lease.
27
28
22. NO PRIOR OR OTHER AGREEMENTS; BROKER DISCLAIMER.
This Lease contains all agreements between the Parties with respect to any
matter mentioned herein, and no other prior or contemporaneous agreement or
understanding shall be effective.
23. NOTICES.
23.1. NOTICE REQUIREMENTS.
All notices required or permitted by this Lease shall be in writing and
may be delivered in person (by hand or by courier) or may be sent by
regular, certified or registered mail or U.S. Postal Service Express
Mail, with postage prepaid, or by facsimile transmission, and shall be
deemed sufficiently given if served in a manner specified in this
Paragraph 23. The addresses noted adjacent to a Party's signature on
this Lease shall be that Party's address for delivery or mailing of
notices. Either Party may by written notice to the other specify a
different address for notice, except that upon Lessee's taking
possession of the Premises, the Premises. Shall constitute Lessee's
address for notice. A copy of all notices to Lessor shall be
concurrently transmitted to such party or parties at such addresses as
Lessor may from time to time hereafter designate in writing.
23.2. DATE OF NOTICE.
Any notice sent by registered or certified mail, return receipt
requested, shall be deemed given on the date of delivery shown on the
receipt card, or if no delivery date is shown, the postmark thereon. If
sent by regular mail the notice shall be deemed given forty-eight (48)
hours after the same is addressed as required herein and mailed with
postage prepaid. Notices delivered by United States Express Mail or
overnight courier that guarantee next day delivery shall be deemed given
twenty-four (24) hours after delivery of the same to the Postal Service
or courier. Notices transmitted by facsimile transmission or similar
means shall be deemed delivered upon telephone confirmation of receipt,
provided a copy is also delivered via delivery or mail. If notice is
received on a Saturday, Sunday or legal holiday, it shall be deemed
received on the next business day.
24. WAIVERS.
No waiver by either Lessor or Lessee of the Default or Breach of any term,
covenant or condition hereof by the other, shall be deemed a waiver of any other
term, covenant or condition hereof, or of any subsequent Default or Breach by
the other of the same or of any other term, covenant or condition hereof.
Lessor's or Lessee's consent to, or approval of, any act shall not be deemed to
render unnecessary the obtaining of the other's consent to, or approval of, any
subsequent or similar act by the other requiring approval of the other
hereunder, or be construed as the basis of an estoppel to enforce the provision
or provisions of this Lease requiring such consent. The acceptance of Rent by
Lessor shall not be a waiver of any Default or Breach by Lessee. Any payment by
Lessee may be accepted by Lessor on account of monies or damages due Lessor,
notwithstanding any qualifying statements or conditions made by Lessee in
connection therewith, which such statements and/or conditions shall be of no
force or effect whatsoever
28
29
unless specifically agreed to in writing by Lessor at or before the time of
deposit of such payment.
25. RECORDING.
Either Lessor or Lessee shall, upon request of the other, execute, acknowledge
and deliver to the other a short form memorandum of this Lease for recording
purposes. The Party requesting recordation shall be responsible for payment of
any fees applicable thereto.
26. NO RIGHT TO HOLDOVER.
Lessee has no right to retain possession of the Premises or any part thereof
beyond the expiration or termination of this Lease. In the event that Lessee
holds over, then the Base Rent shall be increased to one hundred fifty percent
(150%) of the Base Rent applicable during the month immediately preceding the
expiration or termination. Nothing contained herein shall be construed as
consent by Lessor to any holding over by Lessee.
27. CUMULATIVE REMEDIES.
No remedy or election hereunder shall be deemed exclusive but shall, wherever
possible, be cumulative with all other remedies at law or in equity.
28. COVENANTS AND CONDITIONS; CONSTRUCTION OF AGREEMENT.
All provisions of this Lease to be observed or performed by Lessee are both
covenants and conditions. In construing this Lease, all headings and titles are
for the convenience of the Parties only and shall not be considered a part of
this Lease. Whenever required by the context, the singular shall include the
plural and vice versa. This Lease shall not be construed as if prepared by one
of the Parties, but rather according to its fair meaning as a whole, as if both
Parties had prepared it.
29. BINDING EFFECT; CHOICE OF LAW.
This Lease shall be binding upon the parties, their successors and assigns and
be governed by the laws of the State in which the Premises are located. Any
litigation between the Parties hereto concerning this Lease shall be initiated
in the county in which the Premises are located.
30. SUBORDINATION; ATTORNMENT; NON-DISTURBANCE.
30.1. SUBORDINATION.
This Lease and any Option granted hereby shall be subject and
subordinate to any ground lease, mortgage, deed of trust, or other
hypothecation or security device (collectively, "Security Device"), now
or hereafter placed upon the Premises, to any and all advances made on
the security thereof, and to all renewals, modifications, and extensions
thereof. Lessee agrees that the holders of any such Security Devices (in
this Lease together referred to as "Lessor's Lender") shall have no
liability or obligation to perform any of the obligations of Lessor
under this Lease. Any Lender may elect to have this Lease and/or any
Option granted hereby superior to the lien of its Security Device by
giving written notice thereof to Lessee, whereupon this Lease and such
Options shall be deemed prior to such Security Device, notwithstanding
the relative dates of the documentation or recordation thereof.
29
30
30.2. ATTORNMENT.
Subject to the non-disturbance provisions of Paragraph 30.3, Lessee
agrees to attorn to a Lender or any other party who acquires ownership
of the Premises by reason of a foreclosure of a Security Device, and
that in the event of such foreclosure, such new owner shall not: (1) be
liable for any act or omission of any prior lessor or with respect to
events occurring prior to acquisition of ownership; (ii) be subject to
any offsets or defenses which Lessee might have against any prior
lessor; or (iii) be bound by prepayment of more than one (1) month's
rent.
30.3. NON-DISTURBANCE.
With respect to Security Devices entered into by Lessor after the
execution of this Lease, Lessee's subordination of this Lease shall be
subject to receiving a commercially reasonable non-disturbance agreement
(a "NON-DISTURBANCE AGREEMENT") from the Lender which Non-Disturbance
Agreement provides that Lessee's possession of the Premises, and this
Lease, including any options to extend the term hereof, will not be
disturbed so long as Lessee is not in Breach hereof and attorns to the
record owner of the Premises. Further, within sixty (60) days after the
execution of this Lease, Lessor shall use its commercially reasonable
efforts to obtain a Non-Disturbance Agreement from the holder of any
pre-existing Security Device which is secured by the Premises. In the
event that Lessor is unable to provide the Non-Disturbance Agreement
within said sixty (60) days, then Lessee may, at Lessee's option,
terminate this Lease so long as notice of such election to terminate is
given to Lessor within ten (10) days following the end of such sixty
(60) day period.
30.4. SELF-EXECUTING.
The agreements contained in this Paragraph 30 shall be effective without
the execution of any further documents; provided, however, that, upon
written request from Lessor or a Lender in connection with a sale,
financing or refinancing of the Premises, Lessee and Lessor shall
execute such further writings as may be reasonably required to
separately document any subordination, attornment and/or Non-Disturbance
Agreement provided for herein.
31. ATTORNEYS' FEES.
If any Party brings an action or proceeding involving the Premises to enforce
the terms hereof or to declare rights hereunder, the Prevailing Party (as
hereafter defined) in any such proceeding, action, or appeal thereon, shall be
entitled to reasonable attorneys' fees. Such fees may be awarded in the same
suit or recovered in a separate suit, whether or not such action or proceeding
is pursued to decision or judgment. The term, "Prevailing Party" shall include,
without limitation, a Party who substantially obtains or defeats the relief
sought, as the case may be, whether by compromise, settlement, judgment, or the
abandonment by the other Party of its claim or defense. The attorneys' fees
award shall not be computed in accordance with any court fee schedule, but shall
be such as to fully reimburse all attorneys' fees reasonably incurred. In
addition, Lessor shall be entitled to attorneys' fees, costs and expenses
incurred in the preparation and service of notices of Default and consultations
in connection therewith, whether or not a legal action is subsequently commenced
in connection with such Default or resulting Breach.
30
31
32 LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS.
See Addendum Paragraph 58
33 AUCTIONS.
Lessee shall not conduct, nor permit to be conducted, any auction upon the
Premises without Lessor's prior written consent. Lessor shall not be obligated
to exercise any standard of reasonableness in determining whether to permit an
auction.
34. SIGNS.
Except for ordinary "For Sublease" signs, Lessee shall not place any sign upon
the Premises without Lessor's prior written consent. All signs must comply with
all Applicable Requirements.
35. TERMINATION; MERGER.
Unless specifically stated otherwise in writing by Lessor and except as provided
in a non-disturbance agreement between Lessor and any subtenant, the voluntary
or other surrender of this Lease by Lessee, the mutual termination or
cancellation hereof, or a termination hereof by Lessor for Breach by Lessee,
shall automatically terminate any sublease or lesser estate in the Premises;
provided, however, that Lessor may elect to continue any one or all existing
subtenancies. Lessor's failure within ten (10) days following any such event to
elect to the contrary by written notice to the holder of any such lesser
interest, shall constitute Lessor's election to have such event constitute the
termination of such interest.
36. CONSENTS.
Except as otherwise provided herein, wherever in this Lease the consent of a
Party is required to an act by or for the other Party, such consent shall not be
unreasonably withheld or delayed. Lessor's actual reasonable costs and expenses
(including, but not limited to, architects', attorneys', engineers' and other
consultants' fees) incurred in the consideration of, or response to, a request
by Lessee for any Lessor consent, including, but not limited to, consents to an
assignment, a subletting or the presence or use of a Hazardous Substance, shall
be paid by Lessee upon receipt of an invoice and supporting documentation
therefor. Lessor's consent to any act, assignment or subletting shall not
constitute an acknowledgment that no Default or Breach by Lessee of this Lease
exists, nor shall such consent be deemed a waiver of any then existing Default
or Breach, except as may be otherwise specifically stated in writing by Lessor
at the time of such consent. The failure to specify herein any particular
condition to Lessor's consent shall not preclude the imposition by Lessor at the
time of consent of such further or other conditions as are then reasonable with
reference to the particular matter for which consent is being given. In the
event that either Party disagrees with any determination made by the other
hereunder and reasonably requests the reasons for such determination, the
determining party shall furnish its reasons in writing and in reasonable detail
within ten (10) business days following such request.
37. GUARANTOR.
37.1. EXECUTION.
31
32
The Guarantors, if any, shall each execute a guaranty in the form most
recently published by the American Industrial Real Estate Association,
and each such Guarantor shall have the same obligations as Lessee under
this Lease.
37.2. DEFAULT.
It shall constitute a Default of the Lessee if any Guarantor fails or
refuses, upon request to provide: (a) evidence of the execution of the
guaranty, including the authority of the party signing on Guarantor's
behalf to obligate Guarantor, and in the case of a corporate Guarantor,
a certified copy of a resolution of its board of directors authorizing
the making of such guaranty, (b) current financial statements, (c) a
Tenancy Statement, or (d) written confirmation that the guaranty is
still in effect.
38. QUIET POSSESSION.
Subject to payment by Lessee of the Rent and performance of all of the
covenants, conditions and provisions on Lessee's part to be observed and
performed under this Lease, Lessee shall have quiet possession and quiet
enjoyment of the Premises during the term hereof.
39. OPTIONS.
39.1. DEFINITION.
"OPTION" shall mean: (a) the right to extend the term of or renew this
Lease or to extend or renew any lease that Lessee has on other property
of Lessor; (b) the right of first refusal or first offer to lease either
the Premises or other property of Lessor; (c) the right to purchase or
the right of first refusal to purchase the Premises or other property of
Lessor.
39.2. INTENTIONALLY OMITTED.
39.3. MULTIPLE OPTIONS.
In the event that Lessee has any multiple Options to extend or renew
this Lease, a later Option cannot be exercised unless the prior Options
have been validly exercised.
39.4. EFFECT OF DEFAULT ON OPTIONS.
(a) Lessee shall have no right to exercise an Option: (i) during
the period commencing with the giving of any notice of Default and
continuing until said Default is cured, (ii) during the period of time
any Rent is unpaid (without regard to whether notice thereof is given
Lessee), (iii) during the time Lessee is in Breach of this Lease which
Breach has not been cured, or (iv) in the event that Lessee has been
given three (3) or more notices of separate Default, whether or not the
Defaults are cured, during the six (6) month period immediately
preceding the exercise of the Option.
(b) The period of time within which an Option may be exercised
shall not be extended or enlarged by reason of Lessee's inability to
exercise an Option because of the provisions of Paragraph 39.4(a).
32
33
(c) An Option shall terminate and be of no further force or
effect, notwithstanding Lessee's due and timely exercise of the Option,
if, after such exercise and prior to the commencement of the extended
term, (1) Lessee fails to pay Rent for a period of thirty (30) days
after such Rent becomes due (without any necessity of Lessor to give
notice thereof), (ii) Lessor gives to Lessee three (3) or more notices
of separate Default, whether or not the Defaults are cured, or (iii) if
Lessee commits a Breach of this Lease which Breach has not been cured.
40. MULTIPLE BUILDINGS.
If the Premises are a part of a group of buildings controlled by Lessor, Lessee
agrees that it will observe all reasonable rules and regulations which Lessor
may make from time to time for the management, safety, and care of said
properties, including the care and cleanliness of the grounds and including the
parking, loading and unloading of vehicles, and that Lessee will pay its fair
share of common expenses incurred in connection therewith.
41. SECURITY MEASURES.
Lessee hereby acknowledges that the rental payable to Lessor hereunder does not
include the cost of guard service or other security measures, and that Lessor
shall have no obligation whatsoever to provide same. Lessee assumes all
responsibility for the protection of the Premises, Lessee, its agents and
invitees and their property from the acts of third parties.
42. RESERVATIONS.
Lessor reserves to itself the right, from time to time, to grant, without the
consent or joinder of Lessee, such easements, rights and dedications that Lessor
deems necessary, and to cause the recordation of parcel maps and restrictions,
so long as such easements, rights, dedications, maps and restrictions do not
unreasonably interfere with the use of the Premises by Lessee, or the
interconnection of the Premises with adjacent premises, as contemplated by
Addendum Paragraph 60. Lessee agrees to sign any documents reasonably requested
by Lessor to effectuate any such easement rights, dedication, map or
restrictions.
43. PERFORMANCE UNDER PROTEST
If at any time a dispute shall arise as to any amount or sum, of money to be
paid by one Party to the other under the provisions hereof, the Party against
whom the obligation to pay the money is asserted shall have the right to make
payment "under protest" and such payment shall not be regarded as a voluntary
payment and there shall survive the right on the part of said Party to institute
suit for recovery of such sum. If it shall be adjudged that there was no legal
obligation on the part of said Party to pay such sum or any part thereof, said
Party shall be entitled to recover such sum or so much thereof as it was not
legally required to pay.
44. AUTHORITY.
If either Party hereto is a corporation, trust, limited liability company,
partnership, or similar entity, each individual executing this Lease on behalf
of such entity represents and warrants that he or she is duly authorized to
execute and deliver this Lease on its behalf. Each Party shall, within thirty
(30) days after request, deliver to the other Party satisfactory evidence of
such authority.
33
34
45. CONFLICT.
Any conflict between the printed provisions of this Lease and the typewritten or
handwritten provisions shall be controlled by the typewritten or handwritten
provisions.
46. OFFER.
Preparation of this Lease by either Party or their agent and submission of same
to the other Party shall not be deemed an offer to lease to the other Party.
This Lease is not intended to be binding until executed and delivered by all
Parties hereto.
47. AMENDMENTS.
This Lease may be modified only in writing, signed by the Parties in interest at
the time of the modification. As long as they do not materially change Lessee's
obligations hereunder, Lessee agrees to make such reasonable non-monetary
modifications to this, Lease as may be reasonably required by a Lender in
connection with the obtaining of normal financing or refinancing of the
Premises.
48. MULTIPLE PARTIES.
If more than one person or entity is named herein as either Lessor or Lessee,
such multiple Parties shall have joint and several responsibility to comply with
the terms of this Lease.
49. MEDIATION AND ARBITRATION OF DISPUTES.
An Addendum requiring the Mediation of all disputes between the Parties and/or
Brokers arising out of this Lease x is is not attached to this Lease.
--- ---
LESSOR AND LESSEE HAVE CAREFULLY READ AND REVIEWED THIS LEASE AND EACH TERM AND
PROVISION CONTAINED HEREIN, AND BY THE EXECUTION OF THIS LEASE SHOW THEIR
INFORMED AND VOLUNTARY CONSENT THERETO. THE PARTIES HEREBY AGREE THAT, AT THE
TIME THIS LEASE IS EXECUTED, THE TERMS OF THIS LEASE ARE COMMERCIALLY REASONABLE
AND EFFECTUATE THE INTENT AND PURPOSE OF LESSOR AND LESSEE WITH RESPECT TO THE
PREMISES.
[SIGNATURES APPEAR ON THE FOLLOWING PAGE]
34
35
[THIS IS THE SIGNATURE PAGE FOR THAT CERTAIN LEASE DATED OCTOBER 15, 1999 BY AND
BETWEEN CHAMPAGNE BUILDING GROUP, LP AS LESSOR AND SKECHERS USA, INC. AS LESSEE
WITH RESPECT TO PROPERTY LOCATED AT 0000 X. XXXXXXXXX XXXXXX, XXXXXXX]
The parties hereto have executed this Lease at the place and on (the dates
specified above their respective signatures.
Executed at: Manhattan Beach, Calif. Executed at: Manhattan Beach, CA
On: 11/16/99 On: November 15, 1999
By LESSOR: By LESSEE:
Champagne Building Group, LP, a California Skechers USA, Inc., a Delaware
limited partnership corporation
D and D Champagne, LLC, California limited
liability company, General Partner
By: XXXXXX X. XXXXXXX By: XXXXX XXXXXXXX
Name Printed: XXXXXX X. XXXXXXX Name Printed: Xxxxx Xxxxxxxx
Title: Managing Member Title: Chief Financial Officer
By: [SIGNATURE ILLEGIBLE] By: Xxxxxx Xxxxxxxx
Name Printed: [ILLEGIBLE] Name Printed: Xxxxxx Xxxxxxxx
Address: 0000 Xxxxxxxxxx Xxxxx, Xxxxx 000 Address: 000 Xxxxxxxxx Xxxxx Xxxx.
Xxxxxxx Xxxxx, XX 00000 Xxxxxxxxx Xxxxx, XX 00000
Telephone: 000-000-0000 Telephone: 000-000-0000
Facsimile: 000-000-0000 Fascimile: 000-000-0000
35
36
LEGAL DESCRIPTION
THE LAND REFERRED TO HEREIN IS SITUATED IN THE STATE OF CALIFORNIA, COUNTY OF
SAN BERNARDINO, AND IS DESCRIBED AS FOLLOWS:
PARCELS 18 AND 23 OF PARCEL MAP NO. 9252, AS SHOWN BY MAP ON FILE IN BOOK 107
PAGE(S) 75 THROUGH 82, INCLUSIVE, OF PARCEL MAPS, RECORDS OF SAN BERNARDINO
COUNTY, CALIFORNIA;
ALSO EXCEPTING THEREFROM ALL MINERAL AND ALL MINERAL RIGHTS, OIL AND GAS AND
RIGHTS THERETO TOGETHER WITH SOLE, EXCLUSIVE AND PERPETUAL RIGHT TO EXPLORE FOR,
REMOVE AND DISPOSE OF, SAID MINERALS BY ANY MEANS OR METHODS SUITABLE, BUT
WITHOUT ENTERING UPON OR USING THE SURFACE OF SAID LANDS AND IN SUCH A MANNER AS
NOT TO DAMAGE SURFACE OF SAID LANDS OR TO INTERFERE WITH THE USE THEREOF, AS
CONVEYED TO UNION PACIFIC LAND RESOURCES CORPORATION BY DEED RECORDED NOVEMBER
23, 1982 AS INSTRUMENT NO. 82-234011 OF OFFICIAL RECORDS.
37
EXHIBIT A
WORK LETTER
38
EXHIBIT A
WORK LETTER
0000 XXXXXXXXX XXXXXX, XXXXXXX, XX
SKECHERS USA, INC as Tenant and CHAMPAGNE BUILDING GROUP LP as Landlord
are executing, simultaneously with this Work Letter, a Standard
Industrial/Commercial Single-Tenant Lease-Net (the "Lease"), covering
certain Premises at 0000 X. Xxxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxxxx as
more particularly described in the Lease. This Work Letter is hereby
incorporated into such Lease as an Exhibit thereto. In consideration of
the mutual covenants contained in the Lease, Tenant and Landlord hereby
agree that the Premises shall be improved in accordance with the
provisions of this Work Letter. To the extent that this Work Letter
conflicts with any provision in the Lease, the provision of this Work
Letter shall govern.
1.1 BASE BUILDING AND RENT.
Landlord and Tenant understand and acknowledge that Landlord has agreed
to construct and deliver the "Base Building" to Tenant in exchange for
Tenant's agreement to pay the Rent and comply with the other terms and
conditions of the Lease.
1.1.1 BASE BUILDING BY LANDLORD.
The "Base Building" shall be constructed by Landlord's
contractor at Landlord's sole cost and expense, except for
Tenant's responsibilities for portions of the Base Building as
set forth in Section 1.1.1.2, in accordance with the "Building
Plans and Specifications" identified on the List of Building
Plans and Specifications attached as Schedule 2 to this Work
Letter, and as closely as reasonably possible substantially in
accordance with the Preliminary Construction Schedule attached
as Schedule 3 to this Work Letter. The "Base Building" is
defined as and is described with particularity in the Building
Plans and Specifications and includes, among other things, the
items described in Section 1.1.1.1. If there is any conflict
between the items described as included in Section 1.1.1.1
and the items of work included in the Building Plans and
Specifications, the Building Plans and Specifications shall
govern. The Base Building shall be constructed in a good and
workmanlike manner and shall comply with all applicable laws,
ordinances and codes, and the rules and regulations of all
governmental authorities having jurisdiction and shall comply
with all applicable insurance regulations.
1.1.1.1 INCLUDED IN BASE BUILDING.
The "Base Building" shall include, among other things,
the following elements of the Building:
1.1.1.1. DESIGN, ARCH, ENGINEERING AND CITY
PROCESSING.
For building modification to raise the clear
height from 30' clear to 39'6" clear;
1
39
1.1.1.2. OFFICE.
Office space at the north side of the warehouse
of approximately 2,800 square feet to include
three private offices approximately 12 feet x 15
feet. Restrooms to include: one men's with 3
stalls, 3 sinks, 3 urinals, one women's with 5
stalls, 3 sinks. Lunchroom of approximately
1,125 square feet and shall be accessible to the
warehouse. Lunchroom and restrooms are per
Architect specifications;
1.1.1.3. LIGHTING.
Metal halide warehouse lighting for 20-foot
candles (assuming 7 fixtures per aisle for 38
aisles at racking area and on fixture at 30 foot
x 32 foot on center in the balance of the
building to achieve the 20 foot candles).
Racking and aisle alignment information obtained
from W.E.I., Skechers' consultant;
1.1.1.4. TRUCK LOADING.
Forty dock high (8'6" x 10") door with dock seal
and light package. W.E.I. spec for 40 doors.
Blue giant edge of dock levelers Model MD72255M
with seal and light package.
1.1.1.1.1 Electrical for lighting and fans
between every other door. 20 4-plex 20 amp
plugs.
1.1.1.1.2 12'xl4' ground level doors at the
north and south end of the building.
1.1.1.1.3 Ramp in back of the building at the
rail door. Enlarge door. (12x14).
1.1.1.1.4 Provide two (2) dock high doors on the
back of the north side (on the curve) of the
building.
1.1.1.1.5 Provide two (2) paved pathways in back
of the facility to allow forklift access between
the new and existing facilities.
1.1.1.5. CLEAR HEIGHT
39'6" (except for the 1st 6' in front of the
loading area by truck doors). This area will be
38';
1.1.1.6. FOIL INSULATED CEILING.
Upgrade the foil to multi-layer over the mezz
area room grid 13 to 19. Approximately 60,000
square feet at 30 cents per foot;
1.1.1.7. SKYLIGHT.
2
40
Two and one-half percent (2 1/2%);
1.1.1.8. FANS.
Code-1/2 air change per hour. One additional air
changes in total building. Two air changes in
north 60,000 square feet in mezz area;
1.1.1.9. SPRINKLERS.
ESFR Specification using K-25 high capacity head
increasing pipe size and flow rate so not to
need pump;
1.1.1.10 FLOOR.
Floor spec 6" thick with 4000 P.S.I. tensile
strength;
1.1.1.11 POWER.
2000 amp, 480/227 Volts, 3 Phase Sub panel to
battery charging forklifts, 20 stations;
1.1.1.12 OUTSIDE LIGHTING.
Per Building Plans and specifications.
1.1.1.2 TENANT BASE BUILDING RESPONSIBILITIES.
Tenant has agreed to accept the responsibility to
separately pay for the following items of Base Building
work ("Tenant Base Building Responsibilities") even
though such items are included within the Building Plans
and Specifications:
1.1.1.2.1 ROOF TRUSSES.
Roof trusses have been modified and reengineered
to carry additional loads to support Tenant's
conveyor system per W.E.L spec and Tenant shall
separately pay for the increased costs due to
such modifications, which costs are agreed to be
$17,300;
1.1.1.2.2 PAYMENT BY TENANT.
Upon execution of the Lease, Tenant shall pay to
Landlord in cash an amount equal to the
estimated cost of the item described in Section
1.1.1.2.1 as such amount is set forth in such
Section.
1.1.1.3 TENANT REVIEW OF BUILDING PLANS AND
SPECIFICATIONS.
3
41
Tenant has reviewed and approved the plans and
specifications for the Base Building including, without
limitation, the Base Building design, Base Building
systems, parking structure, and floor plans referred to
on Schedule 2 (collectively, the "Building Plans").
Landlord may make changes to Building Plans without
Tenant's consent provided that such changes do not
change the size or the exterior dimensions of the
Premises, do not cause changes to the Tenant
Improvements, do not delay Tenant's construction of the
Tenant Improvements, and provided further that the Base
Building, when constructed in accordance with such
revised Building Plans and Specifications, shall be
comparable to, or better than, the Base Building
described in the Building Plans and Specifications
approved by Tenant.
1.2. TENANT IMPROVEMENTS.
The provisions of this Work Letter pertaining to the construction of
Tenant Improvements shall apply only to the extent that Tenant elects to
construct improvements within the Premises. Such provisions shall not be
interpreted to "require" Tenant to build any Tenant Improvements. The
provisions of this Work Letter relating to Tenant Improvements shall
apply to the installation by Tenant of Tenant's contemplated "material
handling system".
1.2.1. TENANT'S GENERAL CONTRACTOR.
Tenant, through Tenant's general contractor (who shall first be
approved by Landlord, which approval shall not be unreasonably
withheld or delayed), shall construct within the Premises those
improvements (the "Tenant Improvements") shown on the Tenant's
Final Space Plans (including, without limitation, the Tenant
Base Building Responsibilities), as approved by the Landlord and
Tenant pursuant to Section 2 below. Landlord hereby approves WEI
as Tenant's general contractor. All Tenant Improvements shall be
constructed pursuant to this Work Letter and shall be performed
only by Tenant's general contractor pursuant to a construction
contract approved by Landlord as set forth in Section 4.1.1.
Tenant shall be responsible for the coordination and supervision
of the construction of the Tenant Improvements by Tenant's
general contractor. Tenant agrees that Tenant's general
contractor shall be licensed and fully insured in the
construction of the Tenant Improvements.
1.2.2. TENANT FACILITIES.
Tenant shall have the opportunity to incorporate special Tenant
facilities ("Tenant Facilities") into the Premises as part of
the Tenant Improvements including, without limitation, a
material handling system, facilities for computers, telephone
equipment rooms, file rooms, and other special facilities
incidental to Tenants operations; provided, however, as follows:
1.2.2.1. COMPLIANCE WITH LAWS.
4
42
All such Tenant Facilities shall comply with all
applicable laws, ordinances and codes, and the rules and
regulations of all governmental authorities having
jurisdiction;
1.2.2.2. FLOOR LOAD WEIGHTS.
The projected load weights per square foot for such
areas shall be within the limits set forth in the
Building Plans (unless such floors are capable of being
reinforced, and Tenant, at Tenant's sole expense,
reinforces the floors as, necessary);
1.2.2.3. COMPLIANCE WITH INSURANCE.
All such Tenant Facilities shall comply with all
applicable insurance regulations;
1.2.2.4. LANDLORD APPROVAL OF SPECIFICATIONS.
The specifications for such Tenant Facilities have been
reasonably approved by Landlord as consistent with the
design and engineering specifications for the Base
Building;
1.2.2.5. REQUIRED CHANGES TO BASE BUILDING WORK.
To the extent such Tenant Facilities require changes to
the Base Building, such changes shall be made by
Landlord, at Tenant's cost (all such work shall be
charged to Tenant at competitive rates which would be
charged by qualified third party contractors of similar
quality and reputation as Landlord's contractor if such
work were bid out);
1.2.2.6. DELAYS CAUSED BY TENANT FACILITIES.
To the extent the inclusion of such Tenant Facilities or
the construction of the Tenant Improvements causes
delays of the Substantial Completion of the Base
Building by Landlord, the date on which the Landlord
shall be deemed to have delivered the Base Building for
all purposes with respect to this Work Letter and the
Lease shall be the date upon which Landlord would have
delivered the Base Building but for the delays
attributable to Tenant Facilities requested by Tenant
hereunder.
2. PLANS AND SPECIFICATIONS FOR TENANT IMPROVEMENTS
2.1. TENANT CONSULTANTS.
Tenant shall retain an architect of its choice and, at Tenant's
election, a space planner, each subject to Landlord's approval (which
shall not be unreasonably withheld or delayed) to prepare the plans and
specifications described hereinafter for the Tenant Improvements.
5
43
2.2. TENANT SCHEMATIC SPACE PLANS.
Tenant shall cause its architect (or space planner) to furnish to
Landlord for Landlord's approval (which shall not be unreasonably
withheld) space plans sufficient to convey the architectural design of
the Premises, including without limitation, the location of doors,
partitions, electrical and telephone outlets, plumbing fixtures, heavy
floor loads and other special requirements, together with reflective
ceiling plans, and plans for any improvements to be constructed outside
of the Base Building ("Tenant's Schematic Space Plans"). Landlord's
approval or disapproval shall be given within ten (10) days of receipt
of such plans. If Landlord shall reasonably disapprove of any portion of
Tenant's Schematic Space Plans, Landlord shall advise Tenant of
Landlord's required revisions, and the reasons therefor. Tenant shall
then submit to Landlord, for Landlord's approval, a redesign of Tenant's
Schematic Space Plans, incorporating the revisions required by Landlord,
as modified by Tenant, which modifications must be approved by Landlord
prior to Tenant's submission of the "Tenant's Final Space Plans" (as
such term is defined below).
2.3. TENANT'S FINAL SPACE PLANS.
Tenant shall cause its architect (or space planner) to prepare from
Tenant's approved Tenant's Schematic Space Plans complete architectural
plans, drawings and specifications and, utilizing Landlord's mechanical,
electrical, life safety and structural engineers, complete engineered
mechanical, electrical, life safety, sprinkler, plumbing and structural
working drawings for (a) all of the Premises, showing the subdivision,
and layout desired by Tenant therefor, and (b) any internal or external
communications or special utility facilities which will require
conduiting, or other improvements within the Base Building, all in such
form and in such detail as may be reasonably required by Landlord
(collectively, "Tenant's Final Space Plans"). Tenant's Final Space Plans
shall (i) be compatible with the Base Building and with the design and
construction of and the equipment and systems within the Base Building
including, without limitation, the heating, ventilating and air
conditioning, life safety, sprinkler, plumbing and electrical systems;
(ii) comply with all applicable laws, ordinances and codes, and the
rules and regulations of all governmental authorities having
jurisdiction; and (iii) comply with all applicable insurance
regulations. Tenant shall submit the Tenant's Final Space Plans for the
approval (which shall not be unreasonably withheld or delayed) of
Landlord and otherwise in the same manner as provided in Section 2.2
above for approval by Landlord of Tenant's Schematic Space Plans.
2.4. QUALITY OF TENANT IMPROVEMENTS.
The Tenant Improvements shall not require extraordinary building
services (unless Tenant agrees to pay the excess actual costs associated
therewith) or overload the floors. Any required floor reinforcements
above the floor load levels set forth in Building Plans shall be at
Tenant's cost.
2.5. RESPONSIBILITY FOR GOVERNMENTAL APPROVALS.
6
44
2.5.1. TENANT IMPROVEMENTS.
Tenant (or its architect or space planner) shall be responsible,
at Tenant's sole cost, for obtaining approval of the Tenant's
Final Space Plans by all governmental agencies having
jurisdiction of the Premises, together with all other
governmental approvals with respect to the installation of the
Tenant Improvements, including any necessary building permits and
all other necessary permits and the temporary and permanent
Certificates of Occupancy for the Premises.
2.5.2. BASE BUILDING WORK.
Landlord or Landlord's engineers, at Landlord's cost, shall
obtain all necessary approvals, permits and licenses specifically
required for the Base Building, including without limitation,
electrical, mechanical and structural engineering of the Base
Building. Landlord shall reasonably cooperate with Tenant in
obtaining all other necessary approvals and permits.
2.6. INSPECTION BY LANDLORD.
From time to time during Tenant's construction of the Tenant
Improvements, Landlord may inspect the work in place upon the Premises
for compliance with the Tenant's Final Space Plans.
3. ALLOWANCE FOR WORK AND WORK COST.
3.1. TENANT IMPROVEMENT ALLOWANCE.
Tenant shall receive NO allowance from Landlord for the construction of
the Tenant Improvements. All Tenant Improvement work shall be contracted
by Tenant and the entire Work Cost for any Tenant Improvements shall be
paid directly by Tenant.
3.2. CHANGES TO BASE BUILDING WORK.
If the Tenant's Final Space Plans or any amendment thereof or supplement
thereto shall require changes in the Base Building including any change
to accommodate Tenant's Tenant Facilities or the Tenant Improvements
pursuant to Section 1.2.2 above, and such proposed changes are
acceptable to Landlord, in its reasonable discretion, the cost of such
changes shall be paid directly by Tenant. The cost of such changes to
the Base Building shall include all direct architectural and/or
engineering fees and expenses in connection therewith, including plan
check and inspection fees. Landlord shall notify Tenant within ten (10)
days following Landlord's receipt of Tenant's Final Space Plans whether
or not and, if so, to the estimated extent, shall require changes in the
Base Building.
3.3. PAYMENT OF TENANT IMPROVEMENT WORK COSTS.
7
45
Tenant shall be responsible for and shall pay directly all costs of the
Tenant Improvements and Landlord shall have no responsibility therefor.
3.4. CHANGES TO PLANS.
In the event that changes to the Tenant's Schematic Space Plans or
Tenant's Final Space Plans are requested by Tenant or required by any
governmental agency subsequent to Landlord's approval thereof, except
for non-material changes, such changes and the costs thereof shall be
forwarded to Landlord for approval (which approval shall not be
unreasonably withheld) prior to incorporation into the work, provided,
however, that Landlord shall be obligated to approve any changes
required by any governmental agency. After Landlord's approval of the
changes and the costs thereof, the changes shall be incorporated into
the work by means of a change order.
4. CONSTRUCTION.
4.1. CONSTRUCTION OF TENANT IMPROVEMENTS.
Upon written notice from Landlord that the Base Building has been
sufficiently completed and/or the Premises are reasonably available for
the construction of the Tenant Improvements hereunder and the Tenant
make now take Early Possession (as defined in Paragraph 3.2 of the
Lease), Tenant shall have the right, but not the obligation, to take
Early Possession and to direct Tenant's contractor to immediately
commence and diligently complete construction of the Tenant
Improvements.
4.1.1. LANDLORD APPROVAL OF CONSTRUCTION CONTRACT.
Such construction shall be carried out pursuant to a
construction contract approved in writing by Landlord, which
approval shall not be unreasonably withheld or delayed. Such
construction contract shall provide for retention of ten percent
(10%) of the monthly progress payments. Landlord shall have the
right, but not the obligation, to demand that Tenant promptly
cause its contractor(s) to correct any or the following or, if
so ordered by Landlord, to stop the work upon the occurrence of
any of the following:
4.1.1.1. LIENS.
In the event any materialmen's, mechanic's or other lien
is filed against the Premises and not promptly removed,
or in the event all subcontractors are not compensated
in due course for work performed with respect to the
construction of the Tenant Improvements;
4.1.1.2. POOR WORKMANSHIP.
If any portion of the Tenant Improvements constructed
under Tenant's direction is of inadequate or inferior
quality or workmanship and Tenant does not diligently
proceed to replace or repair such inadequate or inferior
work upon written notice from Landlord;
8
46
4.1.1.3. TENANT VIOLATION.
If the contractor fails in any material way to adhere to
the provisions of the Lease, including, without
limitation, the provisions of this Work Letter, and such
violation has not been remedied within five (5) business
days of Tenant's receipt of written notice from
Landlord, or if such violation is of a nature such that
it can not be reasonably cured within a five (5)
business days period, if Tenant or its contractor has
not commenced to cure within such period and diligently
proceeded to cure thereafter;
4.2. TENANT IMPROVEMENT SCHEDULE.
Prior to commencement of any Tenant Improvement work in the Premises,
Tenant shall furnish for approval to Landlord in writing a schedule
setting forth projected completion dates and showing the deadlines for
any actions required to be taken by Landlord and Tenant during such
construction.
4.3. LANDLORD APPROVAL OF TENANT SUBCONTRACTORS.
Landlord shall have the right to approve all subcontractors designated
by Tenant or Tenant's agents or contractor for work on the Premises with
respect to construction of the Tenant Improvements which subcontractors
work is material to the construction of the Tenant Improvements or
material in relation to the Base Building, which approval shall not be
unreasonably withheld or delayed, and which approval or disapproval
shall be given by Landlord within ten (10) days after Tenant submits a
list of subcontractors for Landlord's approval. Landlord hereby approves
WEI as a subcontractor for Tenant.
4.4. REQUIREMENTS FOR CARRYING OUT LANDLORD'S AND TENANT'S WORK.
Landlord and Tenant agree that all construction work shall be carried
out at such times as Landlord directs, in accordance with reasonable
rules and regulations, promulgated by Landlord and in such a manner as
to minimize as much as reasonably possible interference with the work of
either Landlord or Tenant, and, without limiting the generality of the
foregoing, in accordance with the following:
4.4.1. QUALITY WORK.
Such work shall be performed in a good and workmanlike manner
and in accordance with all applicable laws.
4.4.2. BONDS, LICENSE AND INSURANCE.
Prior to Tenant commencing work on the Premises, Tenant shall
cause Tenant's contractor to furnish to Landlord, at Tenant or
Tenant's contractor's cost, and Landlord shall cause Landlord's
contractor to furnish to Tenant, at Landlord or Landlord's
contractor's cost, (i) evidence satisfactory to the other that
such party's contractor has a valid and appropriate license; and
(ii) sufficient evidence that such
9
47
contractor is carrying workmen's compensation insurance in
statutorily required amounts, together with general liability
insurance naming Landlord or Tenant, as the case may be, its
lender and its managing agent as additional insureds in such
limits and with such insurers as are reasonably appropriate
under the circumstances.
4.4.3. LANDLORD RIGHT TO INSPECT.
Landlord shall have the right to enter the Premises at all times
to inspect the work and to post notices of nonresponsibility.
4.4.4. NO LIENS.
Tenant shall ensure lien free completion of the Tenant
Improvement Work and Landlord shall ensure lien free completion
of the Base Building. If a lien is filed and is attributable to
the work of the other, the party responsible shall within thirty
(30) days of receiving written notice thereof either discharge
such lien or, if such party determines to contest such lien,
post a bond in accordance with Section 3143 of the California
Civil Code releasing the Building and Premises from such lien.
If such party fails to discharge such lien or to post such bond
to discharge such lien, the other party shall have the right to
discharge such lien and to xxxx the other party for the cost
thereof, which cost shall be reimbursed to the party posting
such bond within five (5) business days.
4.4.5 CONCURRENT WORK.
It is Landlord's intention to permit Tenant to take Early
Possession of the Premises on or before March 1, 2000. When
Landlord permits Tenant to take Early Possession, it is likely
that Landlord's work on the Base Building will not be complete.
Landlord and Tenant agree that if Tenant takes Early Possession
before Substantial Completion of the Base Building has occurred
that both Landlord and Tenant will cooperate with the other and
instruct their respective contractors and subcontractors to
cooperate with those of the other and to minimize the
interference with the work of the other.
4.4.6 UNION LABOR.
Each of Landlord and Tenant has indicated to the other that they
intend to use only non-union labor for work on the Premises.
Each party agrees that prior to Landlord or Tenant or their
respective contractors or subcontractors permitting union trades
to perform work on the Premises, the party so permitting union
trades will first notify the other party and shall obtain and
deliver to the other party a certificate of non-interference so
that injunctive relief would be available should the union
trades attempt to interfere with the activities of the non-union
trades.
If either Landlord or Tenant or their respective contractors or
subcontractors invite or acquiesce in union trades performing
work on the Premises and if union
10
48
interference should arise during the course of construction as a
result of such union trades performing work on the Premises, the
party responsible for such union trades performing work on the
Premises shall be responsible for promptly resolving such
interference and as to such responsible party, such interference
shall NOT constitute a Force Majeure event. On the other hand,
such interference SHALL constitute a Force Majeure event as to
the party not so responsible for such interference.
In the event of union interference that is not the
responsibility of either Landlord or Tenant as described in the
preceding paragraph, then the party targeted by such union
interference shall be responsible for resolving such
interference as expeditiously as possible. To the extent any
such interference occurs, such interference shall constitute a
Force Majeure event for both Landlord and Tenant.
5. TENANT ACCESS.
5.1. LANDLORD TO PROVIDE ACCESS.
Landlord shall upon and after the Early Possession Date, during
the hours set for in Schedule 1 to this Work Letter ("Access
Hours"), provide Tenant and Tenant's employees, space planners,
architects, contractors and subcontractors, reasonable access to
the Premises, along with adequate electricity and lighting
available to the Premises for the purpose of constructing the
Tenant Improvements and installing Tenant's furniture, fixtures,
equipment (including telephone, communications and computer
equipment) and personal property for use in the Premises.
5.2. STOCKING OF MATERIALS.
All stocking of major materials for use in the Tenant Improvements shall
be performed after regular business hours.
5.3. SUBJECT TO LANDLORD'S RULES & REGULATIONS.
Subject to Section 5.1 above, Tenant's rights of access, construction
and installation hereunder shall be subject to the reasonable rules and
the direction of Landlord.
5.4. FREE OF LANDLORD MATERIALS.
Tenant's Lease space shall be free of any debris, and any material or
inventory stored by Landlord, prior to Tenant's move-in to the Premises.
6. INDEMNIFICATION.
Tenant hereby indemnifies Landlord and agrees to protect, defend and hold
Landlord, its constituent members, affiliates, partners, and their respective
agents, officers and employees, harmless from and against any and all losses,
costs, liabilities, damages,
11
49
demands, claims, causes of action and expenses (including attorneys' fees and
court costs) by reason of damage to the Base Building, Premises or the property
of others and/or personal injury, including death, which may arise from the
Tenant Improvement work in the Premises, whether caused by Tenant, Tenant's
contractor or any subcontractor, or anyone directly or indirectly employed by
any of them.
Landlord hereby indemnifies Tenant and agrees to protect, defend and hold
Tenant, its constituent members, affiliates, partners, and their respective
agents, officers and employees, harmless from and against any and all losses,
costs, liabilities, damages, demands, claims, causes of action and expenses
(including attorneys' fees and court costs) by reason of damage to the Base
Building, Premises or the property of others and/or personal injury, including
death, which may arise during the construction of the Base Building, whether
caused by Landlord, Landlord's contractor or any subcontractor, or anyone
directly or indirectly employed by any of them.
7. MISCELLANEOUS.
7.1. TENANT'S ENTRY INTO THE PREMISES PRIOR TO SUBSTANTIAL COMPLETION.
Contractor shall allow Tenant and/or Tenant's agents access to the
Premises as of the Early Possession Date prior to the Substantial
Completion of the Base Building for the purpose of Tenant and/or
Tenant's agents constructing the Tenant Improvements and installing
equipment or fixtures (including Tenant's data and telephone equipment
and related cabling) in the Premises.
7.2. TENANT'S REPRESENTATIVE.
Tenant has designated Xxxx Xxxxxxxx as its sole representative with
respect to the matters set forth in this Tenant Work Letter, who, until
further notice to Landlord, shall have full authority and responsibility
to act on behalf of the Tenant as required in this Tenant Work Letter.
7.3. LANDLORD'S REPRESENTATIVE.
Landlord has designated Xxxxxx Xxxxxxx as its sole representative with
respect to the matters set forth in this Tenant Work Letter, who, until
further notice to Tenant, shall have full authority and responsibility
to act on behalf of the Landlord as required in this Tenant Work Letter.
7.4. PUNCH LIST ITEMS.
Within thirty (30) days of the Substantial Completion of the Premises,
Tenant shall provide Landlord a punch list (latent and hidden defects
excepted), which punch list shall consist of those decorative and minor
mechanical type adjustments which do not materially interfere with
Tenant's use of the Premises. Upon receipt of the punch list,
12
50
Landlord shall, at Landlord's sole cost and expense, proceed to
diligently remedy all such items within forty-five (45) days of such
receipt.
7.5. MISCELLANEOUS CHARGES.
During the period of construction of the Tenant Improvements and
Tenant's move into the Premises, neither Tenant nor Tenant's agents
shall not be charged for, directly or indirectly, parking, restrooms,
HVAC usage, electricity, water, elevator usage, loading dock usage,
freight elevator usage, or security.
7.6. STAGING AREA STORAGE SPACE.
During the period commencing on the date of this Lease and prior to the
Commencement Date, Tenant shall have the right, without the obligation
to pay rent, to use such portion of the Premises designated by Landlord
for the purposes of storing and staging Tenant's property. With respect
to this free storage space, Tenant shall provide all insurance and any
necessary fencing or other protective facilities. Tenant shall hold
Landlord harmless and indemnify Landlord from and against any and all
loss, liability or cost arising out of or in connection with use of this
storage space by Tenant, except to the extent caused by the negligence
or willful misconduct of Landlord.
7.7. SECOND STORY OFFICE.
Landlord acknowledges that Tenant may elect to add a second story to the
"office" portion of the Premises. The first floor of such "office" is
included as part of the Base Building. If Tenant elects to add the
second story at any time, such work will be treated as a Tenant
Improvement and shall be processed and constructed in accordance with
the terms and conditions therefor set forth in this Work Letter.
Landlord hereby consents to Tenant's adding such second floor so long as
Tenant otherwise complies with this Work Letter as to the construction
of such second story addition. Landlord agrees that if Tenant adds such
second floor, such second floor will become part of the Premises, and
Tenant will not be required to remove it at the expiration of Lease.
INITIALS OF LANDLORD INITIALS OF TENANT
/s/ [Signature Illegible] /s/ [Signature Illegible]
----------------------------------- -----------------------------------
13
51
SCHEDULE 1 TO WORK LETTER
CONTRACTOR RULES AND REGULATIONS
0000 X. XXXXXXXXX XXXXXX, XXXXXXX, XX
The following are the Rules and Regulations for construction personnel
performing work as contractors or suppliers of Tenant at 0000 X. Xxxxxxxxx
Xxxxxx, Xxxxxxx, Xxxxxxxxxx.
1.1 BUILDING ACCESS
1.1.1 PARKING
All personnel shall park on the portion of the Premises
designated for such purpose by Landlord from time to time.
1.1.2 STOCKING OF MATERIALS-LARGE QUANTITIES
Stocking of large amounts of materials to be done between 7:00
p.m. and 7:00 a.m.
1.1.1. STOCKING OF MATERIALS-SMALL QUANTITIES
Stocking of small amounts of materials may be done between 7:00
a.m. and 7:00 p.m.
1.1.2. NO STAGING ON SIDEWALKS OR STREET
No materials may be staged (for ANY length of time) on sidewalks
or the street.
1.2 JOBSITE
1.2.1 TRASH
Food and debris shall be disposed of in trash receptacles. Each
subcontractor shall remove DAILY its construction debris and
trash.
1.2.2 FOOD AND DRINK
No food and drink is allowed in areas where finishes have been
installed; i.e., carpet, paint, wall coverings, etc.
1.2.3 WORK NEAR DEMISING WALLS
When performing work near the demising wall of an adjacent
occupied suite, noisy tasks (screw guns, etc.) must be performed
before 7:30 a.m.
1.2.4 NO DRAGGING ACROSS FLOORS
Ladders, other equipment and materials must not be dragged
across floors.
1.2.5 USE OF RESTROOMS
Restrooms will not be used to fill buckets, make pastes, wash
buckets, etc.
14
52
1.3 SECURITY/PASS DOWNS
Normal working hours are from 7:00 a.m. to 5 p.m.
All work which occurs after normal working hours (between 5 p.m. and
7 a.m.) must be coordinated with the Building Manager.
1.4 FIRE, LIFE SAFETY
Landlord will be notified of all work that affects the various Fire Life
Safety systems in the Building. The electrical subcontractors, sprinkler
subcontractors, and perhaps other subs must contact Landlord's
representative or Landlord's general contractor (via Tenant's general
contractor) to arrange for the Building Engineer to disable smoke
detectors, bring the Building off-line, drain the sprinkler system,
etc., and coordinate inspections with the Ontario Fire Department.
15
53
SCHEDULE 2 TO WORK LETTER
LIST OF BUILDING PLANS AND SPECIFICATIONS
0000 X. XXXXXXXXX XXXXXX, XXXXXXX, XX
SOILS REPORT:
Geotechnical Engineering Investigation, Project Number 8104-99 dated May 12,
1999 by NorCal Engineering.
CIVILS:
Sheets 1 of 5 through 5 of 5, Grading, Sewer and Water Plans red stamped BID SET
SEP 22 1999 by Xxxxxx & Associates.
ARCHITECTURAL:
Project Manual dated September 27, 1999 and Sheets A0.1, A0.2, A0.2-1 through
A0.2-3, A1.1, A2.1, A2.1-R1, A2.1-R2, A2.2, A2.3, A3.1 through A3.6, A4.1
through A4.5, A5.1 and AD.1 through AD.6 red stamped BID SET SEP 22 1999 by Hill
Pinckert Architects.
STRUCTURAL:
Sheets S-1 through S-4, PNL1 through PNL4, SD1 through SD9, SS1 and SW-1
through SW-3 red stamped BID SET SEP 22 1999 by Xxxx Xxxx Associates.
ELECTRICAL:
Sheets XxX, X0X and SL1 red stamped BID SET SEP 22 1999 by Xxxxx Electric.
PLUMBING:
Sheet P-1 red stamped BID SET SEP 22 1999 by C W Plumbing & Design, Inc.
MECHANICAL:
Sheet M1 red stamped BID SET SEP 22 1999 by Air Control Systems Inc.
LANDSCAPE:
Sheets T-1 and L-1 through L-9 red stamped BID SET SEP 22 1999 by Hunter
Landscape Services.
FIRE SPRINKLER:
Sheets 1 of 9 through 9 of 9 red stamped BID SET SEP 22 1999 by X.X. Xxxxxx
Sprinkler Co., Inc.
16
54
Schedule 3 To Work Letter
Preliminary Construction Schedule
[To be Attached]
17
55
CHAMPAGNE PRELIMINARY SCHEDULE
XXXXXXX CONSTRUCTION.....11/4/99
-----------------------------------------------------------------------------------------------------------------------------------
NOVEMBER DECEMBER JANUARY FEBRUARY MARCH
---------------------------------------------------------------------------
11/14 11/29 12/12 12/26 1/9 1/23 2/4 2/20 3/5 3/19
-----------------------------------------------------------------------------------------------------------------------------------
NO. DURATION START FINISH TASK NAME
--------------------------------------------------------
1 6 days 11/15/99 11/24/99 GRADING
--------------------------------------------------------
2 40 days 11/26/99 1/29/00 BLDG CONCRETE
--------------------------------------------------------
3 17 days 11/30/99 12/29/99 SEWER & STORM DRAIN
--------------------------------------------------------
4 10 days 12/21/99 1/2/00 FIRE AND WATER LINES
--------------------------------------------------------
5 10 days 1/4/00 1/17/00 EDISON & PHONE
--------------------------------------------------------
6 3 days 1/18/00 1/20/00 SLEEVES RIGHT OF WAY
--------------------------------------------------------
7 10 days 1/21/00 2/3/00 FOUR APPROACHES
--------------------------------------------------------
8 6 days 1/28/00 2/4/00 LIFT BUILDING &
SCAN WALLS
--------------------------------------------------------
10 4 days 1/31/00 2/5/00 WELD
--------------------------------------------------------
11 4 days 1/31/00 2/3/00 SET COLUMNS
--------------------------------------------------------
13 4 days 2/2/00 2/7/00 WATER BLAST
--------------------------------------------------------
17 20 days 2/3/00 3/1/00 SACK-TRKWELL-GLASS-
REST
--------------------------------------------------------
12 16 days 2/4/00 2/24/00 K-BRACE WORK
--------------------------------------------------------
14 20 days 2/4/00 3/2/00 ROOF STRUCTURE
--------------------------------------------------------
9 2 days 2/7/00 2/9/00 GROUT PANELS
--------------------------------------------------------
16 20 days 2/8/00 3/7/00 SITE CONCRETE
--------------------------------------------------------
?? 25 days 2/11/00 3/18/00 O.H. FIRE SPRINKLERS
--------------------------------------------------------
18 ? days 2/18/00 2/28/00 PERIMETER CONDS/
DRAINS/B.FILL
--------------------------------------------------------
20 8 days 2/23/00 3/1/00 BUILD & LITE CURBS
--------------------------------------------------------
23 2 days 3/2/00 3/3/00 H2O RINSE
BUILDING
--------------------------------------------------------
26 3 days 3/2/00 3/6/00 ROOF SHEET METAL
--------------------------------------------------------
16 3 days 3/3/00 3/6/99 FULL BRACES
--------------------------------------------------------
2? 10 days 3/6/00 3/7/00 FOURSTRIP
--------------------------------------------------------
?? 2 days 3/5/00 3/7/00 CAULK PANEL JOINTS
--------------------------------------------------------
?? 2 days 3/7/00 3/8/00 ROOF INSPECTION &
CORRECT
--------------------------------------------------------
?? 10 days 3/8/00 3/21/00 PRIME PAINT BLDG.
EXT.
--------------------------------------------------------
40 2 days 3/8/00 3/?/00 STAKE C&G
--------------------------------------------------------
31 16 days 3/9/00 3/27/00 ROOFING
--------------------------------------------------------
42 2 DAYS 3/10/00 3/13/00 GRADE C&G
--------------------------------------------------------
---------------------------------------------------------------------------------------------------------
APRIL MAY JUNE
--------------------------------------------------
4/2 4/16 4/30 5/14 5/29 6/11
----------------------------------------------------------------------------------------------------------
NO. DURATION START FINISH TASK NAME
--------------------------------------------------------
1 6 days 11/15/99 11/24/99 GRADING
--------------------------------------------------------
2 40 days 11/26/99 1/29/00 BLDG CONCRETE
--------------------------------------------------------
3 17 days 11/30/99 12/29/99 SEWER & STORM DRAIN
--------------------------------------------------------
4 10 days 12/21/99 1/2/00 FIRE AND WATER LINES
--------------------------------------------------------
5 10 days 1/4/00 1/17/00 EDISON & PHONE
--------------------------------------------------------
6 3 days 1/18/00 1/20/00 SLEEVES RIGHT OF WAY
--------------------------------------------------------
7 10 days 1/21/00 2/3/00 FOUR APPROACHES
--------------------------------------------------------
8 6 days 1/28/00 2/4/00 LIFT BUILDING &
SCAN WALLS
--------------------------------------------------------
10 4 days 1/31/00 2/5/00 WELD
--------------------------------------------------------
11 4 days 1/31/00 2/3/00 SET COLUMNS
--------------------------------------------------------
13 4 days 2/2/00 2/7/00 WATER BLAST
--------------------------------------------------------
17 20 days 2/3/00 3/1/00 SACK-TRKWELL-GLASS-
REST
--------------------------------------------------------
12 16 days 2/4/00 2/24/00 K-BRACE WORK
--------------------------------------------------------
14 20 days 2/4/00 3/2/00 ROOF STRUCTURE
--------------------------------------------------------
9 2 days 2/7/00 2/9/00 GROUT PANELS
--------------------------------------------------------
16 20 days 2/8/00 3/2/00 SITE CONCRETE
--------------------------------------------------------
?? 25 days 2/11/00 3/18/00 O.H. FIRE SPRINKLERS
--------------------------------------------------------
18 ? days 2/18/00 2/28/00 PERIMETER CONDS/
DRAINS/B.FILL
--------------------------------------------------------
20 8 days 2/23/00 3/1/00 BUILD & LITE CURBS
--------------------------------------------------------
23 2 days 3/2/00 3/3/00 H2O RINSE
BUILDING
--------------------------------------------------------
26 3 days 3/2/00 3/6/00 ROOF SHEET METAL
--------------------------------------------------------
16 3 days 3/3/00 3/6/99 FULL BRACES
--------------------------------------------------------
2? 10 days 3/6/00 3/7/00 FOURSTRIP
--------------------------------------------------------
?? 2 days 3/5/00 3/7/00 CAULK PANEL JOINTS
--------------------------------------------------------
?? 2 days 3/7/00 3/8/00 ROOF INSPECTION &
CORRECT
--------------------------------------------------------
?? 10 days 3/8/00 3/21/00 PRIME PAINT BLDG.
EXT.
--------------------------------------------------------
40 2 days 3/8/00 3/?/00 STAKE C&G
--------------------------------------------------------
31 16 days 3/9/00 3/27/00 ROOFING
--------------------------------------------------------
42 2 DAYS 3/10/00 3/13/00 GRADE C&G
--------------------------------------------------------
56
CHAMPAGNE PRELIMINARY SCHEDULE
XXXXXXX CONSTRUCTION . . . 11/4/99
NOVEMBER DECEMBER JANUARY FEBRUARY MARCH APRIL MAY JUNE
-------- -------- ------- -------- ----- ----- --- ----
ID DURATION START FINISH TASK NAME 11/14 11/28 12/12 12/26 1/9 1/23 2/8 2/20 3/6 3/18 4/2 4/16 4/30 5/14 5/28 6/11
-- -------- ----- ------ --------- ----- ----- ----- ----- --- ---- --- ---- --- ---- --- ---- ---- ---- ---- ----
34 16 days 3/13/00 3/31/00 FOIL AT ROOF
64 4 days 3/13/00 3/16/00 CURB AND
GUTTER
37 11 days 3/14/00 3/30/00 GLAZING
38 2 days 3/18/00 3/18/00 SET ELECT
GEAR
38 11 days 3/18/00 3/30/00 BUILD ELECT
ROOM
46 2 days 3/17/00 3/28/00 FINAL GRADE
WALKS 1ST
22 10 days 3/20/00 3/31/00 DOCK
EQUIPMENT
27 18 days 3/20/00 4/7/00 ROLL-UP
DOORS
28 4 days 3/20/00 3/23/00 EXT. MAN
DOORS
44 6 days 3/20/00 3/27/00 WALKS & MAN
DR. PADS
60 2 days 3/24/00 3/23/00 CLEAN & REAL
FLOOR
36 12 days 3/24/00 4/10/00 HI-BAY LITES
83 2 days 3/24/00 3/31/00 BASE & PAVE
P.LOT
32 7 days 3/30/00 4/7/00 SKYLITES
33 8 days 3/30/00 4/8/00 ROOF EXHAUST
UNITS
41 1 day 3/30/00 3/30/00 CAULK
SCUPPERS
43 3 days 3/31/00 4/4/00 DOWNSPOUTS
47 1 day 3/31/00 3/31/00 EDISON/GTE
ENERGIZED
38 8 days 3/31/00 3/31/00 RACKS BEGIN
IF CITY
"OK"(S)
49 8 days 4/2/00 4/12/00 FENCE &
GATES
51 2 days 4/3/00 4/12/00 STRIPE P.LOT
88 20 days 4/4/00 6/1/00 LANDSCAPE
38 2 days 4/5/00 4/8/00 HAND RAILS &
TRASH
GATES
64 8 days 4/16/00 4/17/00 FINISH EXT.
BLDG.
PAINT
65 10 days 5/2/00 5/15/00 BLDG. FINALS
29 0 days 5/16/00 5/16/00 JOB COMPLETE
57
EXHIBIT B
PROTECTED LESSEE OWNED ALTERATIONS
[TO BE LISTED BY LESSEE AND ATTACHED]
58
EXHIBIT B
PROTECTED LESSEE OWNED ALTERATIONS
Material Handling system whose components include, but are not limited to, the
following:
A tilt tray sorter, conveyor (consisting of, among other things, certain
mechanical equipment, spiral chutes, spiral declines and truck loaders),
platforms and pick modules (which platforms and pick modules consist of, among
other things, a main platform, induction platforms, level modules, shelving,
fire protection, lighting and footings), case sealers, in-line scales and
auto-tie bailers
59
ADDENDUM
[TO BE ATTACHED]
60
ADDENDUM TO INDUSTRIAL/COMMERCIAL
SINGLE-TENANT LEASE - NET
LESSOR: Champagne Building Group, LP, a California limited partnership
LESSEE: Skechers USA, Inc., a California Corporation
LEASE DATED: October 15, 1999
The following provisions are added to that certain Standard
Industrial/Commercial Single-Tenant Lease-Net dated for reference purposes as of
October 15, 1999, by and between Champagne Building Group LP, a California
limited partnership, as Lessor, and Skechers, USA, Inc., a California
Corporation, as Lessee. In the event of any conflict between the terms of the
Printed Lease and this Addendum, the terms of this Addendum shall control.
50. Rent: For the first sixty (60) months of the original term of the lease the
Base Rent is $85,693.00 net per month. Beginning on the sixty-first (61st) month
and continuing until the eighty-fourth (84th) month, the Base Rent shall be
$92,285.00 net per month.
51. [intentionally omitted]
52. Option to Extend Term: Lessee shall have one option (the "Option") to extend
the Term of the Lease for a period of five (5) years (hereafter the "Option
Period"), provided that all of the following conditions are satisfied: (a)
Lessee shall provide Lessor with written notice (the "Option Exercise Notice")
of Lessee's election to exercise the Option not less than one hundred eighty
(180) nor more than three hundred sixty (360) days prior to the expiration of
the Original Term of the Lease, and (b) no default by Lessee of its obligations
under this Lease shall have occurred and be continuing, either at the time
Lessee delivers the Option Exercise Notice to Lessor or at the commencement of
the Option Period. The Base Rent for Option Period shall be equal to ninety-five
percent (95%) of the Fair market Rental Value (as defined below) for comparable
industrial buildings in the City of Ontario, but in no event shall the monthly
Base Rent for Option Period be less than the monthly Base Rent for the last
month of the Original Term.
52.1 Upon receipt by Lessor of an Option Exercise Notice, Lessor and Lessee
shall confer and attempt to agree upon the initial monthly Base Rent for the
Option Period. If such an agreement is not reached within thirty (30) days
following the receipt of such notice by Lessor, then Fair Market Rental Value
("FMRV") for the Premises shall be determined as provided in Paragraph 52.2
below.
52.2 To determine FMRV, Lessor shall engage at its sole cost and expense a MAI
certified appraiser ("Lessor's Appraiser") who shall render a written opinion of
the FMRV for the Premises ("Lessor's FMRV"). Lessee shall have five (5) business
days to accept or reject Lessor's FMRV. If Lessee accepts Lessor's FMRV, Lessee
shall reimburse Lessor for one-half of the fees and expenses of Lessor's
Appraiser. If Lessee rejects such determination of FMRV, Lessee shall engage at
its sole cost and expense a second Independent MAI certified appraiser
("Lessee's Appraiser") who shall also render a written opinion of the FMRV for
the Premises ("Lessee's FMRV"). If Lessor's FMRV is less than 10% greater or
less than Lessee's FMRV, then the FMRV for the Premises shall be the average of
Lessor's FMRV and Lessee's FMRV. If the difference
1
61
between Lessor's FMRV and Lessee's FMRV is 10% or more, and Lessor and Lessee
cannot agree between themselves as to the FMRV for the Premises, then FMRV shall
be determined by a third independent MAI certified appraiser (the "Third
Appraiser") mutually selected by Lessor's Appraiser and Lessee's Appraiser;
provided, however, in no event will the FMRV be less than the lowest of Lessor's
FMRV and Lessee's FMRV nor higher than the highest of Lessor's FMRV and Lessee's
FMRV. The Third Appraiser shall render a written opinion of the FMRV for the
Premises, which shall be binding and conclusive upon Lessor and Lessee. The
costs of the Third Appraiser shall be shared equally by Lessor and Lessee.
Except for the option to extend the term of the Lease for one (1), five (5) year
period as provided in this Xxxxxxxxx 00, Xxxxxx shall have no other option to
extend the term of the Lease, or option to purchase, option to lease or right of
first refusal.
53. Premises Total Destruction. The following language replaces the language
contained in Paragraph 9.1(b) of the Lease:
"(b) "Premises Total Destruction" shall mean damage or destruction to
improvements on the Premises, other than Lessee Owned Alterations and
Utility Installations and Trade Fixtures, which cannot reasonably be
repaired within six (6) months or less from the date of the damage or
destruction. Within thirty (30) days following the date of the damage or
destruction, Lessor shall select a general contractor ("Lessor's
Contractor") who shall, by written notice to Lessor and Lessee (a
"Determination Notice"), determine whether or not the repair of such
damage or destruction can be completed within six (6) months from the date
of the damage or destruction. If Lessee elects not to accept such
determination by Lessor's Contractor, Lessee shall, at Lessee's sole
expense, select another general contractor ("Lessee's Contractor") who
shall, within ten (10) days after receipt by Lessee of such Determination
Notice, by written notice to Lessor and Lessee, determine whether or not
the repair of such damage or destruction can be completed within six (6)
months from the date of the damage or destruction. Should Lessor's
Contractor and Lessee's Contractor fail to agree upon whether such damage
or destruction can be repaired within six (6) months from the date of the
damage or destruction, then the matter shall be resolved by binding
arbitration in accordance with the Rules of the American Arbitration
Association."
54. Partial Damage-Uninsured Loss. The following language replaces the first
two sentences of Paragraph 9.3 of the Lease:
"If a Premises Partial Damage occurs that is not an Insured Loss, unless
caused by a negligent or willful act of Lessee (in which event Lessee
shall make the repairs at Lessee's expense), (i) if the total cost of
repairing such damage is reasonably determined by an impartial general
contractor selected by Lessor to be equal to or less than $250,000, then
Lessor shall repair such damage (but not Lessee's Trade Fixtures or Lessee
Owned Alterations and/or Utility Installations), and (ii) if the total
cost of repairing such damage is reasonably determined by an impartial
general contractor selected by Lessor to be greater than $250,000, then
Lessor may either (A) repair such damage (but not Lessee's Trade Fixtures
or Lessee Owned Alterations and/or Utility Installations) as soon as is
reasonably possible at Lessor's expense, in which event the Lease shall
remain in full force and effect, or (B) terminate the Lease by giving
written notice to Lessee (a
2
62
"Termination Notice") within thirty (30) days after the date that Lessor
becomes aware of the occurrence of such damage, such termination to be
effective one hundred twenty (120) days after the date of such notice;
provided, however, that the Lease shall not so terminate if Lessee, by
written notice to Lessor within thirty (30) days after receipt of such
Termination Notice, elects to repair such damage (after Lessor's payment
of the foregoing $250,000 sum) at Lessee's sole expense."
55. Damage Near End of Term. The following language replaces the language
contained in the first sentence of Paragraph 9.5 of the Lease:
"If at any time during the last six (6) months of the Original Term (as
the same may be extended) there is damage to the Premises for which the
cost of repairs is reasonably estimated by an impartial general contractor
selected by Lessor to exceed one-month's then Base Rent, whether or not an
Insured Loss, Lessor or Lessee may, by written notice to the other party
within thirty (30) days after the date of occurrence of such damage,
terminate this Lease effective sixty (60) days following the date of
occurrence of such damage."
56. Assignment and Subletting-Lessor's Consent Required. The following
language is added as a new Paragraph 12.1(b) of the Lease:
"(b) Lessee shall have the right, without Lessor's consent but after prior
notice to Lessor including the name, address and contact information of
such assignee, to assign the Lease to an entity (an "Affiliate")
controlling, under common control with, or controlled by Lessee, including
an entity resulting from a merger or consolidation by Lessee, provided
that the Affiliate assumes in writing Lessee's obligations under this
Lease in the proportion that the number of square feet of the Premises
transferred to the Affiliate of Lessee bears to the total number of square
feet in the Premises, without relieving Lessee of any liability under the
Lease. Any such Affiliate assignee shall be deemed to have assumed all
liabilities of Lessee hereunder. Lessee or such Affiliate assignee shall
provide such additional information relating to such Affiliate assigned as
Lessor shall request from time to time."
57. Condemnation. The following language is inserted after the third sentence
of Paragraph 14 of the Lease:
"Condemnation awards and/or payments shall be the property of Lessor,
whether such award shall be compensation for diminution in value of the
Premises, the value of the part taken, or for severance damages; provided,
however, that Lessee shall be entitled to any portion of such condemnation
award specifically attributable to (i) Lessee's loss of business goodwill
and/or Trade Fixtures, and (ii) if this Lease is terminated pursuant to
the provisions of Paragraph 14 of the Lease, Lessee's reasonable
relocation expenses and any excess of the market value of the Premises for
the remainder of the Original Term (as the same may be extended) over the
present value as of the date of such termination of the Base Rent payable
for the remainder of the Original Term (as the same may be extended)."
58. Lessor's Access; Showing Premises; Repairs. The following language
replaces the language contained in Paragraph 32 of the Lease:
3
63
"Lessor and Lessor's agents shall have the right to enter the Premises at
any time, in the case of an emergency, and otherwise, upon 24 hours' prior
notice to Lessee, for the purpose of showing same to prospective
purchasers, lenders, or lessees, and making alterations, repairs,
improvements and additions to the Premises as Lessor may deem necessary.
All such activities shall be without abatement of rent or liability to
Lessor. Lessor may at any time place one commercially standard,
free-standing "For Sale" sign at a location to be selected by mutual
agreement of Lessor and Lessee near the perimeter of the Premises. Lessor
may at any time during the last six (6) months of the Original Term (as
the same may be extended) place one commercially standard, free-standing
"For Lease" sign at a location to be selected by Lessor near the perimeter
of the Premises. Lessee may at any time place one commercially standard,
free-standing "For Sublease" sign at a location to be selected by Lessee
near the perimeter of the Premises."
59. Substantial Completion. For purposes of determining the Commencement Date
under Paragraph 1.3 of the Lease, "Substantial Completion" shall mean and
refer to the following:
"Substantial Completion" shall mean that point in time when Landlord's architect
certifies that construction of the Base Building is substantially complete in
accordance with the Work Letter so that Tenant can legally occupy and utilize
the Premises in accordance with City laws and regulations. Tenant acknowledges
that Tenant will be constructing Tenant Improvements, including without
limitation, racking and material handling system pursuant to a separate permit
from the City and in accordance with the Work Letter. "Substantial Completion"
shall have occurred upon the satisfaction of the conditions of the first
sentence of this Section whether or not Tenant shall have completed its Tenant
Improvements."
60 Connection to Neighboring Property. Tenant currently occupies, itself or
through one or more Affiliates, facilities on properties that are adjacent
to the Premises. Tenant has expressed its desire to connect its material
handling system from the Premises to such adjacent facilities. Landlord
consents to the connection of such systems, and will cooperate with Tenant
in establishing such connection (including, without limitation, the
performance of any reasonable acts or the execution of any reasonable
documents acknowledging such Landlord consent), provided, however, that
Tenant is solely responsible (i) for any and all expenses related to and
(ii) for obtaining all permissions and consents, from governmental
entities as well as adjacent property owners, necessary to permit such
connections to be lawfully made. Tenant agrees to indemnify and hold
Landlord harmless from and against any and all liability, loss, cost or
damage arising out of the construction, installation and maintenance of
any facilities for the connection of such systems. THIS LEASE IS NOT
CONDITIONED IN ANY WAY UPON TENANT OBTAINING SUCH PERMISSIONS AND
CONSENTS.
61 Delay in Commencement Date. Landlord agrees to use its best commercially
reasonable efforts to cause Substantial Completion to have occurred on or
before the Scheduled Commencement Date. If, despite said efforts, and
subject to extension of the Scheduled Completion Date on account of Delays
Caused by Tenant and Force Majeure Delays (both as hereinafter defined)
and subject to Tenant's obligation to mitigate its damages,
4
64
Substantial Completion has not occurred prior to the Scheduled
Commencement Date, Landlord shall indemnify and hold Tenant harmless for
Tenant's actual expenses and damages incurred as a result of Substantial
Completion being delayed beyond the Scheduled Commencement Date; PROVIDED,
HOWEVER, IN NO EVENT SHALL THE TOTAL OF DAMAGES PAYABLE FROM LANDLORD TO
TENANT EXCEED $2,600 FOR EACH DAY SUBSTANTIAL COMPLETION IS DELAYED BEYOND
THE SCHEDULED COMPLETION DATE (AS EXTENDED) OR $156,000 IN TOTAL. In the
event Landlord fails to reimburse Tenant as herein set forth, then among
the other remedies available to Tenant, Tenant shall have the right to
offset its expenses, damages, losses and liabilities against Base Rent.
62. Delays Caused by Tenant. "Delays Caused by Tenant" shall mean any actual
delay in the Substantial Completion of the Base Building, caused by an act
or omission of Tenant, its agents or contractors in performing Tenant's
obligations under the Lease, including, without limitation, the following:
- Interference by Tenant. Delays due to interference by Tenant, its
agents or contractors with the completion of the Base Building; or
- Delays in Permits or Approvals. Delays in Landlord obtaining
governmental approvals or permits due to the acts or omissions of
Tenant, its agents or contractors, whether relating to the Tenant
Improvements or otherwise.
63. Force Majeure Delays. "Force Majeure Delay(s)" shall mean any actual delay
due to: fire, earthquake, abnormal rains or other acts of God; acts of
public enemy, war, rioting, insurrection, or other civil commotion; and
strikes or boycotts or the unavailability or critical materials or
workmen, which is or are beyond the reasonable control of Landlord or its
contractors.
64. Extension of Scheduled Commencement Date. The Scheduled Commencement Date
shall be extended one (1) day for each day in which there is either a
Delay Caused by Tenant or a Force Majeure Delay; provided, however, if the
Scheduled Commencement Date is so extended by more than sixty (60) days,
then Tenant may elect to terminate this Lease upon ten (10) days notice to
Landlord unless the Scheduled Commencement Date occurs prior to the end of
such ten (10) day period, in which latter event the Lease shall not
terminate.
65. Tenant Obligation to Mitigate. In the event that the Commencement Date has
not occurred on or before the Scheduled Commencement Date, as extended,
Tenant shall make a good faith effort to reasonably mitigate its damages.
Tenants reasonable costs of mitigation shall be included within the actual
expenses and damages for which Landlord has agreed to indemnify Tenant
pursuant to Paragraph 61 of this Addendum. Without limiting the generality
of the obligation to mitigate its damages, at a minimum, Tenant agrees to
use commercially reasonable efforts: (i) to attempt to extend its current
rights to remain in its current premises at 0000 Xxxx Xxxxxx Xxxxxx, Xxxx
xx Xxxxxxx, Xxxxxxxxxx (the "Current Premises"); (ii) to holdover in the
Current Premises under the provisions, if any, of the current lease
therefor; and/or (iii) to delay its subtenant in taking occupancy of the
5
65
Current Premises. Under no circumstances shall Tenant be required to commence
any legal proceedings in connection with such mitigation efforts.
6
66
Mediation Addendum
MEDIATION OF DISPUTES: LANDLORD AND TENANT AGREE TO MEDIATE ANY DISPUTE OR CLAIM
BETWEEN THEM ARISING OUT OF THIS LEASE (AND WORK LETTER) BEFORE RESORTING TO
ARBITRATION OR COURT ACTION. Mediation is a process in which parties attempt to
resolve a dispute by submitting it to an impartial, neutral mediator who is
authorized to facilitate the resolution of the dispute but who is not empowered
to impose a settlement on the parties. Mediation fees, if any, shall be divided
equally among the parties involved. Before the mediation begins, the parties
agree to sign a document limiting the admissibility in arbitration or any civil
action of anything said, any admission made, and any documents prepared, in the
course of the mediation, consistent with Evidence Code Section 1119. IF ANY
PARTY COMMENCES AN ARBITRATION OR COURT ACTION BASED ON A DISPUTE OR CLAIM TO
WHICH THIS PARAGRAPH APPLIES WITHOUT FIRST ATTEMPTING TO RESOLVE THE MATTER
THROUGH MEDIATION, THEN IN THE DISCRETION OF THE ARBITRATOR(S) OR JUDGE, THAT
PARTY SHALL NOT BE ENTITLED TO RECOVER ATTORNEY'S FEES EVEN IF THEY WOULD
OTHERWISE BE AVAILABLE TO THAT PARTY IN ANY SUCH ARBITRATION OR COURT ACTION.
However, the filing of a judicial action to enable the recording of a notice of
pending action, for order of attachment, receivership, injunction, or other
provisional remedies, shall not in itself constitute a loss of the right to
recover attorney's fees under this provision. The following matters are excluded
from the requirement of mediation hereunder: (a) an unlawful detainer action,
(b) the filing or enforcement of a mechanic's lien, and (c) any matter which is
within the jurisdiction of a probate court.
/s/ [Signature Illegible] /s/ [Signature Illegible]
----------------------------------- -----------------------------------
Lessor's Initial Lessee's Initials
