1
EXHIBIT 10.18
Dated May 20, 1994
ENERGY CONVERSION AGREEMENT
for
A COAL FIRED THERMAL POWER STATION
AT SUAL PANGASINAN, PHILIPPINES
Between
NATIONAL POWER CORPORATION
and
CEPA PANGASINAN ELECTRIC LIMITED
2
TABLE OF CONTENTS
Heading
Article 1 Definition of Terms ......................................................
Article 2 Scope of Agreement ....................................................... 8
Article 3 Construction of the Power Station ........................................ 11
Article 4 Testing .................................................................. 18
Article 5 Operation of the Power Station ........................................... 20
Article 6 Supply of Fuel ........................................................... 22
Article 7 Supply of Electricity, Fees and Foreign Exchange ......................... 24
Article 8 Transfer of Ownership and Buyout ......................................... 28
Article 9 Representations and Warranties of CEPA ................................... 31
Article 10 Representations and Warranties of NPC .................................... 32
Article 11 Taxes .................................................................... 33
Article 12 Insurance ................................................................ 33
Article 13 Transmission Line ........................................................ 34
Article 14 Force Majeure ............................................................ 34
Article 15 Reimbursement and Indemnity .............................................. 36
Article 16 Several Obligations ...................................................... 37
Article 17 Notices .................................................................. 37
3
Article 18 Non-Waiver ............................................................... 38
Article 19 Benefit of Agreement ..................................................... 38
Article 20 Dispute Resolution ....................................................... 39
Article 21 Entire Agreement.......................................................... 40
Article 22 Law ...................................................................... 40
Article 23 Disclaimer ............................................................... 40
Article 24 Jurisdiction ............................................................. 40
Article 25 Effect of Article/Section Headings ....................................... 41
Article 26 Separability ............................................................. 41
Article 27 Liability ................................................................ 41
Article 28 Conditions Precedent ..................................................... 42
Article 29 Late Payment ............................................................. 45
Article 30 Counterparts ............................................................. 46
FIRST SCHEDULE
Project Scope and Specifications ......................................... 47
SECOND SCHEDULE
Operating Parameters ..................................................... 55
THIRD SCHEDULE
Penalty on Delays ........................................................ 60
FOURTH SCHEDULE
Specifications for Fuel Supply ........................................... 61
4
FIFTH SCHEDULE
Transmission Line Specifications ................................................... 65
SIXTH SCHEDULE
Electricity Delivery Procedures .................................................... 66
SEVENTH SCHEDULE
Measurement and Recording of Electricity ........................................... 68
EIGHTH SCHEDULE
Delivery of Power and Energy ....................................................... 69
NINTH SCHEDULE
Insurance .......................................................................... 74
TENTH SCHEDULE
Form of Performance Undertaking .................................................... 75
ELEVENTH SCHEDULE
Form of Accession Undertaking ...................................................... 76
TWELFTH SCHEDULE
Form of Legal Opinion of NPC'S GENERAL COUNSEL ..................................... 79
THIRTEENTH SCHEDULE
Test and Inspection ................................................................ 80
FOURTEENTH SCHEDULE
Required Project Description Data For Environmental Impact Assessment Study ........ 85
FIFTEENTH SCHEDULE
Sample Computations of Monthly Billing, Start-Up Charges, Penalties and Incentives.. 87
SIXTEENTH SCHEDULE
Access Road and Specifications ..................................................... 88
EXHIBIT I
Map of the Site and the Proposed Access Road
5
EXHIBIT II
Proposed Meter Location
SIGNATURE PAGE
6
KNOW ALL MEN BY THESE PRESENTS
THIS AGREEMENT is made and entered into by and between:
CEPA PANGASINAN ELECTRIC LIMITED, a private corporation, duly organized and
existing under the laws of the British Virgin Islands with registered office at
X.X. Xxx 00, Xxxxxxxxx Xxxxxxxx, Xxxx Town, Tortola, British Virgin Islands,
represented by its directors, Xxxxxx Xx Xxxx Xxxxxx and Xxxxxxx X.X. Xxxxxxx,
who are duly authorized to represent it in this Agreement, hereinafter referred
to as CEPA
- and -
NATIONAL POWER CORPORATION, a government owned and controlled corporation duly
organized and existing under and by virtue of Republic Act No. 6395, as amended,
with its principal office at the corner of Xxxxx Xxxx xxx Xxxxxx Xxxxxx,
Xxxxxxx, Xxxxxx Xxxx, Xxxxxxxxxxx, represented herein by its President,
Xxxxxxxxx X. Xxxxx, who is duly authorized to represent it in this Agreement,
hereinafter referred to as NPC.
RECITALS
WHEREAS NPC has called for the development of new power facilities to support
and maintain the country's rapid economic growth.
WHEREAS NPC issued to the public a notice inviting interested parties to
prequalify to bid for a coal fired thermal power plant project on a
build-operate-transfer ("BOT") basis.
WHEREAS in response to an invitation to tender from NPC, Hopewell Holdings
Limited, submitted a bid for the construction and operation of an 1,000 MW coal
fired thermal power plant on a BOT basis to be undertaken by its subsidiary,
CEPA, which is a wholly-owned subsidiary of Consolidated Electric Power Asia
Limited, a company to which Hopewell Holdings Limited has, pursuant to a
reorganization completed in late 1993, transferred the majority of all its then
existing and future rights and obligations in relation to its power generation
business.
1
7
WHEREAS NPC, after having evaluated project proposals and selecting the one most
advantageous to NPC, issued a letter of award on 29 April 1994 following which
it was agreed that CEPA would supply a coal fired thermal power station to NPC
on a BOT basis.
WHEREAS pursuant to the said letter, CEPA has agreed to construct and
operate and NPC has agreed to accept electricity generated from a coal fired
thermal power station upon the terms and subject to the conditions hereinafter
set forth.
WHEREAS CEPA has organized a subsidiary Philippine corporation called Pangasinan
Electric Corporation ("CEPA PHILIPPINES") for the purpose of undertaking certain
of the work in respect of the construction and operation of the power station
and performing other undertakings specified in this Agreement.
NOW IT IS HEREBY AGREED as follows:
ARTICLE 1
DEFINITION OF TERMS
1.1 In this Agreement and in the recitals hereto:
"ACCESSION UNDERTAKING" means an agreement substantially in the form
set out in the Eleventh Schedule (Form of Accession Undertaking)
pursuant to which CEPA PHILIPPINES agrees to become a party hereto as
therein provided;
"ACCESS ROAD" means the road or roads referred to in the Sixteenth
Schedule (Access Road and Specifications) and identified as such in the
map contained in Exhibit I;
"ASH DISPOSAL SITES" means the site or sites in Sual, Pangasinan,
identified by CEPA for development as sites for the disposal of ash, as
more particularly described in the First Schedule (Project Scope and
Specifications).
"AVAILABILITY SCHEDULE" means the schedule of the generating capacity
of the Power Station agreed pursuant to Article 5.7;
"BOND" means the standby letter of credit referred to in Article 3.17;
"CAPACITY FEES" means Capital Recovery Fees, Fixed Operating Fees,
Infrastructure Fees and Service Fees;
2
8
"CAPITAL RECOVERY FEES" means the fees payable by NPC to CEPA in
respect of the recovery of CEPA's capital costs incurred in relation to
the Project as provided in Article 7;
"CENTRAL BANK" means the Bangko Sentral ng Pilipinas;
"COAL" means coal supplied for use as the main fuel of the Power
Station in accordance with the provisions of the Fuel Specifications;
"COMPLETION DATE" means the day upon which CEPA certifies that the
Power Station, capable of operation in accordance with the Operating
Parameters, has succesfully completed its testing in accordance with
Article 4, or would have had had NPC performed its obligations under
this Agreement relating to the Site, the Ash Disposal Sites, the Access
Road and the Pipelines, Fuel and electricity for testing and
commissioning and start-up of the Power Station and the taking of
electricity and the Transmission Line in a timely manner;
"COOPERATION PERIOD" means, in relation to a Unit, the period of twenty
five (25) years from the later of Target Completion Date in respect of
such Unit and the Unit Completion Date in respect of such Unit, as the
same may be extended from time to time pursuant to the terms hereto;
"DELIVERY POINTS" means the metering points referred to in the Seventh
Schedule (Measurement and Recording of Electricity);
"ENERGY FEES" means the fees payable by NPC to CEPA in respect of
energy supplied to NPC as provided in Article 7;
"EMERGENCY" means unforeseen circumstances affecting the Luzon grid
which reasonably require NPC to request CEPA to supply it with power
and energy as soon as practicable in order to avoid damage to NPC's
electric system and/or a failure in the continuous supply of
electricity from the grid;
"FINANCIAL CLOSING" means the submission by CEPA to NPC of CEPA's
written confirmation that all loan, export credit, guarantee and other
facilities necessary to finance the portion of the total Project cost
that is not funded by equity or other sources are available to CEPA;
"FIXED OPERATING FEES" means the fees payable by NPC to CEPA in respect
of recovery of CEPA's fixed operating costs incurred in relation to the
Project as provided in Article 7;
"FORCE MAJEURE" shall have the meaning specified in Article 14.1;
3
9
"FUEL" means any and all Coal and Oil;
"FUEL SPECIFICATIONS" means the specifications of fuel for the Power
Station described in Article 6 and the Fourth Schedule (Specifications
for Fuel Supply);
"INFRASTRUCTURE" means the Jetty, the receiving, handling and storage
equipment for Fuel and the Ash Disposal Sites;
"INFRASTRUCTURE FEES" means the fees payable by NPC to CEPA in respect
of the recovery of CEPA's capital costs and debt service and operating
expenses incurred in relation to relevant Infrastructure as provided in
Article 7;
"JETTY" means the jetty or wharf referred to in the First Schedule
(Project Scope and Specifications);
"MCR" shall have the meaning specified in Section IV.2 of the First
Schedule (Project Scope and Specifications);
"MILESTONE" means any of the events listed under the column headed
"Milestone" in Article 3.11;
"MONTH" means, with respect to each Unit, the period commencing on the
first day of the Cooperation Period for such Unit and ending upon the
taking of a photograph of the electricity meters pursuant to the
Seventh Schedule (Measurement and Recording of Electricity) on the 25th
of the then current calendar month (or of the next calendar month, if
such Cooperation Period should begin after the 25th of the then current
calendar month), and thereafter each period commencing upon the expiry
of the preceding Month and ending immediately upon the taking of such
photograph on the 25th of the next calendar month, provided that any
Month commencing before, and which would otherwise end after, the last
day of a Cooperation Period shall be adjusted so as to end on the last
day of such Cooperation Period;
"NEDA" means the National Economic and Development Authority;
"NET CONTRACTED CAPACITY" means, in respect of the Power Station, 1,000
MW and, in respect of each Unit, 500 MW;
"NOMINATED CAPACITY" means, with respect to each year from the Unit
Completion Date for an Unit up to the Transfer Date and subject to the
operation of Article 7.19 and Section 2 of
4
10
the Eighth Schedule, the net kilowatt capability nominated by CEPA for
such Unit for such year; such nomination shall be made by CEPA on the
Unit Completion Date of such Unit and, for each year thereafter, not
later than thirty (30) days prior to the anniversary of such Unit
Completion Date;
"OIL" means fuel oil supplied for the start-up and low-load operation
of the Power Station in accordance with the provisions of the Fuel
Specifications;
"OPERATING PARAMETERS" means the operating parameters of the Power
Station and the Units described in the Second Schedule (Operating
Parameters);
"PERFORMANCE COAL" means coal which satisfies Fuel Specifications set
out for Performance Coal in Section I of the Fourth Schedule
(Specifications for Fuel Supply);
"PERFORMANCE UNDERTAKING" means the undertaking by the Republic of the
Philippines substantially in the form set out in the Tenth Schedule
(Form of Performance Undertaking);
"PIPELINES" means the pipelines, intake (including any xxxxx), pumping
stations and related structures outside the battery limits of the Site
to be constructed by CEPA at its cost for the provision of raw water
to the Power Station and, if deemed necessary by CEPA, for the disposal
of ash to the Ash Disposal Sites;
"PLANNED OUTAGE" shall have the meaning given to it in the Sixth
Schedule (Electricity Delivery Procedures);
"POWER STATION" means the power station built, or to be built,
pursuant to this Agreement;
"PROJECT" means the design, construction, equipping, completion,
testing, commissioning and operation of the Power Station;
"RATED CAPACITY" shall have the meaning specified in Section IV.1 of
the First Schedule (Project Scope and Specifications);
"SERVICE FEES" means the fees payable by NPC to CEPA in respect of
return on CEPA's investment in the Project as provided in Article 7;
"SITE" means the site for the Power Station at Sual, Pangasinan,
Philippines as more particularly described in the First Schedule
(Project Scope and Specifications);
5
11
"SITE MOBILIZATION" means the submission by CEPA of its certificate
confirming the commencement of site preparation activities constituted
by the provision at the Site of a site notice board identifying the
name of the Project, its proponents, and the principal consultants
and contractors and a "portcabin" type site office, the arrival at the
Site of heavy equipment for the initial site clearance and levelling
activities and the initiation of ground levelling and grading works at
the Site;
"SPECIFICATIONS" means the specification of the Power Station and the
Units described in the First Schedule (Project Scope and
Specifications);
"TARGET COMPLETION DATE" means, subject to the other provisions of this
Agreement providing for the extension of such dates:
(i) in relation to Unit 1, fifty-eight (58) calendar
months after the date hereof;
(ii) in relation to Unit 2, sixty-one (61) calendar
months after the date hereof;
(iii) in relation to the Power Station, sixty-one (61)
calendar months after the date hereof;
"T-XXXX RATE" means, in respect of any day of which interest based on
such rate is being calculated under this Agreement, the rate per annum
at which Philippine Treasury Bills (with terms of 91 days or if no such
xxxx is issued, such bills which are issued having the term nearest to
91 days) were issued by the Philippine Government on the Friday
immediately preceding such day, or, if there were no Treasury Bills
issued on such Friday, on the day immediately preceding such Friday on
which Treasury Bills were issued Provided that if for 30 days no
Philippine Treasury Bills were issued, then "T-XXXX RATE" shall mean
such alternative rate of interest as may be agreed between CEPA and NPC
at such time, or, in the absence of agreement, the rate per annum
certified and evidenced by CEPA to be its effective cost of borrowing
at such time;
"TRANSFER DATE" means the day following the last day of the Cooperation
Period in respect of Unit 2;
"TRANSMISSION LINE" means the transmission line to be installed and
connected by NPC pursuant to Article 13 and having the specifications
set out in the Fifth Schedule (Transmission Line Specifications);
6
12
"UNIT" means each of the 500 MW coal fired thermal units together with
its ancillary equipment and "UNIT 1" means the first Unit to be
completed and "UNIT 2" means the second Unit to be completed;
"UNIT COMPLETION DATE" means, in relation to a Unit, the day upon which
CEPA certifies that such Unit, capable of operating in accordance with
the Operation Parameters, has successfully completed its testing in
accordance with Article 4 or would have had had NPC performed its
obligations under this Agreement relating to the Site, the Ash Disposal
Sites, the Access Road and the Pipelines, Fuel and electricity for
testing and commissioning and start-up of the Power Station and the
taking of electricity and the Transmission Line in a timely manner;
"UNIT NET HEAT RATE" means, in relation to a Unit, the fuel-heat input
required to generate a KWHR measured at the high-voltage side of the
main transformer of such Unit with its feul-gas desulphurization plant
in operation; and
"UNPLANNED OUTAGE" shall have the meaning given to it in the Sixth
Schedule (Electricity Delivery Procedures).
1.2 Any reference in this Agreement to:-
(i) an "ARTICLE" or a "SCHEDULE" is a reference to an
article hereof or a schedule hereto; and
(ii) "CEPA" shall, upon the execution of the Accession
Undertaking and where the context so requires or
implies (in particular, but without limitation,
Articles 7 and 11), be construed as a reference to
CEPA PHILIPPINES as well.
1.3 In this Agreement:
(i) "$" and "dollar(s)" denote lawful currency of the
United States of America;
(ii) "ps" and "peso(s)" denote lawful currency of the
Republic of the Philippines;
(iii) "MW" denotes a megawatt;
(iv) "KW" denotes a kilowatt;
7
13
(v) "KWHR" denotes a kilowatt hour; and
(vi) "KVA" denotes a kilovolt-ampere.
ARTICLE 2
SCOPE OF AGREEMENT
2.1 DESIGN AND CONSTRUCTION OF POWER STATION. CEPA shall cause and be
responsible for the site survey and investigation, design, development,
construction, completion, equipping, testing and commissioning of a
coal fired thermal power station.
2.2 CONSTRUCTION. The Power Station shall be constructed and equipped in
accordance with the First Schedule (Project Scope and Specifications).
2.3 COST OF CONSTRUCTION. All costs of CEPA in connection with the
construction of the Power Station as provided in Article 2.1 shall be
borne by CEPA. All necessary funding including any available
preferential credits shall be arranged by and be the responsibility of
CEPA.
2.4 THE SITE. NPC shall make the Site available to CEPA, its employees,
contractors, sub-contractors and advisors as from the date hereof and
up to the Transfer Date for the purposes of enabling CEPA to carry out
preliminary contract works, and to construct and operate the Power
Station as contemplated by this Agreement.
2.5 ELECTRICITY. (a) NPC at its cost shall ensure that electricity meeting
the specifications in paragraph 11 of Section IV of the First Schedule
(Project Scope and Specifications) is available on a timely basis to
the Power Station at the terminal point specified in the Fifth Schedule
(Transmission Line Specification) for:
(i) no-load tests prior to the initial synchronization of
each Unit;
(ii) testing and commissioning after initial
synchronization up to Unit Completion Date of each
Unit;
(iii) the start-up of each Unit from time to time during
the period from Unit Completion Date up to the
Transfer Date; and
(iv) the general power requirements of the Power Station
(including electricity for housing, lighting,
airconditioning and water supply, when both Units are
not
8
14
operating) during the period from the commencement
of no-load tests up to the Transfer Date.
(b) Subject to the operation of Article 4.8, all electricity
taken by the Power Station from NPC for load tests and
start-up following a shutdown for Planned Outage or any
Unplanned Outage allowed pursuant to Section 3 of the Sixth
Schedule (Electricity Delivery Procedures), an optional test
under Article 4.8 or pursuant to a dispatch order of NPC shall
be for the account of NPC. All other electricity taken by the
Power Station from NPC shall be paid for by CEPA at NPC's
generally applicable rates for industrial users in the area.
2.6 OPERATION. CEPA shall, at its cost and subject to the other provisions
of this Agreement, operate each Unit from its Unit Completion Date
within the Operating Parameters set out in the Second Schedule
(Operating Parameters).
2.7 RESPONSIBILITIES OF CEPA. CEPA at its own cost shall be responsible
for:
(i) Site development and construction/erection of the
Infrastructure;
(ii) constructing of the Power Station, to the
specifications set out in of the First Schedule
(Project Scope and Specifications) and in compliance
with the requirements of the Environmental Compliance
Certificate;
(iii) the importation and transportation of equipment to
the Site;
(iv) preparation of the Environmental Impact Assessment
Report (including an Environmental Impact Study) and
obtaining the Project's Environmental Compliance
Certificate;
(v) the obtaining of building, construction, operating
and other permits, licences and other approvals for
the Project, and of visas and work permits for
foreign personnel, the recruitment of local labour
and compliance with all local and other regulations
including the payment of all fees and costs thereof
and of any municipal taxes imposed on its
sub-contractors;
(vi) constructing and maintaining the Access Road in
accordance with Article 3.6 and the Sixteenth
Schedule (Access Road and Specifications); and
9
15
(vii) selection of the location and routes for the Ash
Disposal Sites and the Pipelines not later than
three (3) calendar months and six (6) calendar
months, respectively, from date hereof.
2.8 RESPONSIBILITIES OF NPC. NPC at its own cost shall:
(i) assist CEPA with respect to the responsibilities
under Article 2.7 on a best efforts basis;
(ii) install and connect the Transmission Line in
accordance with Article 13 and the Fifth Schedule
(Transmission Line Specifications); and
(iii) provide full access to and from the Site, the Ash
Disposal Sites and all land required in connection
with the Access Road and the Pipelines in accordance
with Articles 2.4 and 3.6.
2.9 FUEL SUPPLY. Until the Transfer Date, NPC shall, at its own cost,
supply and deliver all Fuel for the testing, commissioning and
operation of the Power Station in accordance with the specifications
set forth in this Agreement and the Fourth Schedule (Specifications
for Fuel Supply) and shall take all electricity generated by the Power
Station during testing and commissioning and otherwise at the request
of NPC and shall pay to CEPA fees provided in Article 7.
2.10 OWNERSHIP OF POWER STATION. From the date hereof until the Transfer
Date, CEPA shall, directly or indirectly, own the Power Station and all
the fixtures, fittings, machinery and equipment, on the Site and the
Ash Disposal Sites or used in connection with the Power Station which
have been supplied by it or at its cost. CEPA shall operate and
maintain the Power Station for the purpose of converting Fuel of NPC
into electricity.
2.11 TRANSFER. On the Transfer Date, the Power Station shall be
transferred by CEPA to NPC without the payment of any compensation and
otherwise in accordance with the provisions of Article 8.
2.12 COOPERATION. The parties hereto shall mutually cooperate with each
other in order to achieve the objectives of this Agreement and
performance by each of the parties hereto of their respective
obligations hereunder.
10
16
ARTICLE 3
CONSTRUCTION OF THE POWER STATION
3.1 CONSTRUCTION RESPONSIBILITY. CEPA shall be responsible for the site
survey and investigation, design, construction, equipping, completion,
testing and commissioning of the Power Station and shall commence work
on the date hereof.
3.2 CEPA's RIGHTS. In pursuance of its obligations under Article 3.1, CEPA
shall, amongst other things, have full right to:
(i) call for tenders and award contracts with or without
tender;
(ii) arrange for the preparation of detailed designs and
approve or reject the same;
(iii) appoint and remove consultants and professional
advisers;
(iv) purchase equipment;
(v) appoint, organize and direct staff, manage and
supervise the Project;
(vi) enter into contracts for the supply of materials and
services, including contracts with NPC; and
(vii) do all other things necessary or desirable for the
completion of the Power Station in accordance with
the Specifications and internationally accepted
engineering standards by the Target Completion Dates.
3.3 LOCAL CONTRACTS. In pursuance of its obligations under Article 3.1,
CEPA shall, where possible, award contracts to Philippine contractors
and suppliers of materials and services and employ Philippine nationals
provided that, in its opinion, the quality, delivery times, costs,
reliability, skills, experience and other terms are comparable to those
offered by foreign contractors, or suppliers and personnel.
3.4 MONITOR PROGRESS. NPC shall be entitled at its own cost to monitor the
progress and quality of the construction and installation work provided
that the same does not materially interfere with the works comprising
the Project or expose any person on the Site to any danger. For this
purpose, CEPA shall:
11
17
(i) submit to NPC a monthly report of construction
progress which shall be in such detail as is
reasonable in the circumstances;
(ii) ensure that NPC and any experts appointed by NPC in
connection with the Project are afforded reasonable
access to the Site at times to be agreed with CEPA;
(iii) make available for inspection at the Site copies of
all plans and designs other than the any proprietary
information of CEPA or any sub-contractor in relation
to the Project or any part thereof; and
(iv) within six (6) months of the completion of the Power
Station, supply NPC with one (1) set of reproducible
copies and five (5) sets of white print copies (or
equivalent) of all "as built" plans and designs
required for the operation or maintenance of the
Power Station.
As soon as practicable after the date hereof CEPA and NPC shall
organize a committee to formulate and agree on procedures for
monitoring and reviewing the progress of the design, construction,
equipping, completion and commissioning of the Power Station.
5 DISCLAIMER. NPC and CEPA:
(i) acknowledge that Article 3.4 is intended to provide
NPC with the opportunity to gather data for its own
information only, and that the same shall not be
construed as giving NPC the right to approve,
consider for possible amendment, require any revision
or take any action with respect to designs or other
work on the Power Station, except to indicate any
divergence from the general specifications set out
in the First Schedule (Project Scope and
Specifications);
(ii) agree that in no event shall CEPA be required to
suspend or delay construction or other work pending
submission to NPC of any report, plan or design or
the commencement or completion by NPC of any
inspection, monitoring, review or other action under
Article 3.4;
(iii) accept that any engineering review conducted by NPC
is solely for its own information and accordingly by
conducting such review NPC make, no such
representation as to the engineering soundness of the
Power Station;
12
18
(iv) agree that CEPA shall in no way represent to any
third party that, as a result of any review by NPC,
NPC is responsible for the engineering soundness of
the Power Station; and
(v) agree that CEPA shall, subject to the other
provisions of this Agreement, be solely responsible
for the economic and technical feasibility,
operational capability and reliability of the Power
Station.
3.6 ACCESS ROAD AND PIPELINES. NPC shall, at its own cost, give vacant
possession of all land required in connection with (i) the Access Road
to CEPA by no later than two (2) calendar months after the date hereof
and (ii) the Pipelines to CEPA by no later than six (6) calendar months
after CEPA shall have identified the routes of piping and sites for
related facilities to NPC. NPC hereby warrants to CEPA that from date
of delivery thereof to CEPA up to the Transfer Date, CEPA shall have
continued and uninterrupted use of and access to such land for the
purposes contemplated by this Agreement (including without limitation,
the construction, installation, use, repair and maintenance of the
Access Road and the Pipelines) and, when constructed, of the Access
Road and the Pipelines, in each case at no cost to CEPA. Subject to NPC
complying with the foregoing, CEPA shall, in a timely manner and at its
own cost, ensure that there is provided to the Site the Access Road
capable of taking traffic to and from the Site (and shall maintain and
repair the Access Road to ensure that it is so capable throughout the
Cooperation Period) in accordance with the requirements of the
Sixteenth Schedule (Access Road and Specifications).
3.7 SITE AND ASH DISPOSAL SITES. NPC shall, at its own cost:
(i) within three (3) calendar months of the date hereof
give vacant possession of the Site to CEPA and
deliver a letter to CEPA confirming that it has
obtained vacant possession of the Site and that CEPA
has vacant possession of the Site and may enter,
occupy and use the Site for the purposes contemplated
by this Agreement (including, without limitation,
commencement of works) at no cost to CEPA from the
date thereof and up to and including the Transfer
Date (together with copies, certified to be true
copies of the original by the Corporate Secretary of
NPC, of all documents evidencing or supporting such
confirmation); and
(ii) give vacant possession of the Ash Disposal Sites to
CEPA not later than six (6) calendar months from the
date hereof Provided that, CEPA shall notify NPC of
its choice of the location of the Ash Disposal Sites
within the period specified in Article 2.7 (vii). In
the event that CEPA fails to so notify NPC,
13
19
the six-month period referred to above shall be
extended by the actual number of days CEPA delays in
notifying NPC of its choice of such location.
NPC hereby warrants and guarantees to CEPA that CEPA shall have
peaceful and exclusive possession of, and continued and uninterrupted
use of and access to the Site and the Ash Disposal Sites from the date
of delivery thereof to CEPA up to the Transfer Date. NPC shall, at its
expense, take all steps necessary to ensure that it has registered
legal title to the Site and the Ash Disposal Sites in its name not
later than sixteen (16) calendar months after the date hereof and shall
execute such instruments as may be necessary to permit the annotation
thereon of CEPA's right to use the Site and the Ash Disposal Sites
under this Agreement and the assignment of the same for the purpose of
arranging financing for the Project consistent with Article 19.2. The
Site and the Ash Disposal Sites shall be made available to CEPA at no
cost to CEPA for the periods referred to above and shall not be used by
CEPA for any purpose other than for power generation and support
activities as contemplated herein without the prior consent of NPC.
3.8 CONSULTATION. Where appropriate, CEPA will consult with NPC concerning
the development of the design of the Power Station and if and to the
extent of the operation of the Luzon grid may be affected will discuss
with NPC the possibility of alterations to the Specifications.
3.9 DRAWINGS AND TECHNICAL DETAILS. CEPA shall furnish NPC with three (3)
hard copies and one (1) reproducible copy of the main group of
drawings and technical details such as, but not limited to, the
following:
(i) final arrangement plans for the general layout of
machinery and equipment;
(ii) general and detailed drawings and specifications for
the electro-mechanical work;
(iii) general and detailed design drawings for civil and
architectural works;
(iv) buried pipings, cable trench, sewage lines;
(v) test procedures;
(vi) correction curves for the boiler and turbine
efficiency;
(vii) start-up curve of the boiler and turbine as function
of time for cold and hot starts;
14
20
(viii) energy balance diagrams at the following different loads --
25%, 50%, 75%, 100% and MCR with 0% and 1% make up; and
(ix) operation and maintenance manuals.
3.10 CONFIDENTIALITY. Each of NPC and CEPA agrees that all information and
documents (whether financial, technical or otherwise) obtained by it or
its agents from CEPA or from NPC or its agent's inspections which are
not generally publicly available shall be kept confidential and not
disclosed to any other person or entity without the prior written
approval of CEPA or, as the case may be, NPC, except as required by law
Provided that each of NPC and CEPA may, with the consent of the other,
issue, from time to time, press releases containing non-sensitive
information in relation to the progress of the construction of the
Power Station. This covenant shall survive the termination of this
Agreement.
3.11 PROJECT MILESTONE DATES. The parties shall work together to endeavour
to achieve the timely completion of the Project in accordance with the
following timetable:
TARGET DATE WHICH IS A DATE
FALLING BY THE FOLLOWING NUMBER
OF CALENDAR MONTHS AFTER THE
MILESTONE DATE HEREOF
Submission of Feasibility Study Eleven (11)
Submission of Environmental Impact Study Fifteen (15)
Issue of Environmental Compliance Certificate Eighteen (18)
Financial Closing Twenty-four (24)
Site Mobilization Twenty-five (25)
Target Completion Date of Unit 1 Fifty-eight (58)
Target Completion Date of Unit 2 Sixty-one (61)
Target Completion Date of Power Station Sixty-one (61)
The target date for all Milestones shall be extended automatically by the
number of days beyond the date that is three (3) calendar months from date
hereof that it shall take NPC to comply with the requirement under Article
3.7(i) and/or to submit any of the letters, opinions, endorsements, approvals
and certifications referred to in Article 28.4. It is understood that the
Milestones may be achieved without penalty earlier than the respective target
dates, and not necessarily in the order, specified above.
15
21
3.12 NO FAULT DELAY. In the event that any of the Milestones (a "delayed
Milestone") is not attained by the target date set out against it in
Article 3.11 (as the same may be extended pursuant to this Agreement)
for any reason other than fault of CEPA, its agents, authorized
representatives or contractors, then the target date for each
subsequent Milestone shall be extended by the actual number of days
that the delayed Milestone is delayed. For such purpose, the actual
number of days of delay shall be counted from the original target date
for the delayed Milestone up to the date the delayed Milestone is
finally achieved. Without prejudice to Article 14.4, in the event that
any Milestone is not attained for any reason whatsoever other than due
to a fault of CEPA, its agents, authorized representatives or
contractors within one hundred and eighty (180) days after the target
date specified therefor, then, Article 8.5 shall apply. Without
limiting the generality of the foregoing, any delay in the attainment
of any Milestone by reason of or attributable to the failure by NPC to
obtain vacant possession and use of all land required in connection
with the Access Road and the Pipelines and/or vacant possession and
legal title to the Site and the Ash Disposal Sites in the manner and
within the period contemplated by Articles 3.6 and 3.7 shall be
construed as a delay arising by reason other than due to a fault of
CEPA, its agents, authorized representatives or contractors.
3.13 CEPA DELAY. In the event that, due to the fault of CEPA and through no
fault of NPC, CEPA fails to:-
(i) attain any of the Milestones up to and including
Site Mobilization within ten (10) days after the
target date for such Milestone as set out in
Article 3.11 (as the same may be extended pursuant
to this Agreement), CEPA shall pay NPC for each day
thereafter until such Milestone is attained an
amount specified in Section 1 of the Third Schedule
(Penalty on Delays); and
(ii) complete an Unit in accordance with the First
Schedule (Project Scope Specifications) within
thirty (30) days after the Target Completion Date
for such Unit (as the same may be extended pursuant
to this Agreement), CEPA shall pay NPC for each day
thereafter until the Unit Completion Date for such
Unit as provided in Section 2 of the Third Schedule
(Penalty on Delays),
in each case, the obligation of CEPA to make such payments shall be
secured by and be limited to the amount then available under the Bond.
3.14 PROLONGED DELAY/ABANDONMENT. In the event that due to the fault of CEPA
and through no fault of NPC (i) the Completion Date of the Power
Station has not occurred on or before the
16
22
day falling three hundred and sixty-five (365) days after the Target
Completion Date of the Power Station or (ii) the construction of the
Power Station is deemed to have been abandoned, and in any such case,
in the judgment of NPC after the confirmation of CEPA, it does not
appear reasonably likely that the Completion Date will ever occur, CEPA
shall pay to NPC by way of liquidated damages the balance of the amount
available under the Bond after any amount paid or payable by CEPA to
NPC pursuant to Article 3.13 has been paid but shall have no other
liability in respect of such failure to complete the Power Station and
upon such balance becoming payable, or being paid by CEPA prior to its
becoming due, CEPA shall have no further liability to make payments
pursuant to Article 3.13 or this Article 3.14. For the purposes of this
Agreement, construction of the Power Station shall be deemed to have
been abandoned if CEPA:
(a) notifies NPC in writing that it has terminated all works of
construction (other than following completion) and does not
recommence such works; or
(b) fails to achieve Site Mobilization within three (3) calendar
months after its target date (as the same may be extended
pursuant to this Agreement) other than by reason of Force
Majeure or an act or omission of NPC; or
(c) fails to resume work within one hundred eighty (180) days of
termination or cessation of any event of Force Majeure, other
than by reason of other Force Majeure or act or omission of
NPC and subject always to Articles 14.4 and 14.7.
3.15 SUBSTANTIAL COMPLETION. Upon substantial completion of an Unit and/or
the Power Station, CEPA may certify that such Unit and/or the Power
Station has successfully completed its testing and that accordingly
the Unit Completion Date for such Unit and/or the Completion Date has
occurred notwithstanding that such Unit and/or the Power Station is
unable to produce 500 MW or, as the case may be, 1,000 MW or to
achieve the guaranteed Unit Net Heat Rate and in such event the
payment of the Capacity Fees and Energy Fees Shall be made as provided
in the Eighth Schedule (Delivery of Power and Energy).
3.16 EARLY COMPLETION. If the Unit Completion Date in respect of an Unit
occurs prior to the commencement of its Cooperation Period, then NPC
shall pay to CEPA a bonus on early completion an amount equal to the
Capital Recovery Fees, Infrastructure Fees and Service Fees for the
period commencing on such Completion Date and ending on the day
falling immediately prior to the first day of such Cooperation Period.
3.17 BOND. (a) To secure the payment of its obligations under Articles 3.13
and 3.14, CEPA shall, not later than the date falling three (3)
calendar months from the date hereof, cause the
17
23
issuance to NPC of a standby letter of credit (the "BOND") acceptable
to NPC in the amount of $60,000,000 (the "BASE AMOUNT"). Until the
achievement of Site Mobilization (at which Milestone the amount
available under the Bond shall be fixed at the base amount and shall
no longer be increased), CEPA shall, upon the later of the achievement
of each Milestone from Submission of Feasibility Study through
Financial Closing and the target date for such Milestone, promptly
cause the increase of the amount available under the Bond by an amount
equal to 12.50% of the base amount, without need of demand from NPC.
On the Unit Completion Date in respect of Unit 1, the amount available
under the Bond shall be reduced by an amount equal to 50% of the base
amount.
(b) To secure NPC against abandonment by CEPA of the Power Station
during the period from Completion Date up to Transfer Date, CEPA shall
maintain during each year falling within such period a bond in the
form of a stand-by letter of credit acceptable to and in favor of NPC
(the "O & M BOND") in the face amount of $30,000,000. For purposes of
this Agreement, the Power Station shall be deemed to have been
abandoned if CEPA:
(i) notifies NPC in writing that it has decided to
terminate all operations of the Power Station; or
(ii) fails to resume operation of the Power Station
within one hundred eighty (180) days of termination
or cessation or any event or Force Majeure, other
than by reason of other Force Majeure or act or
omission of NPC and subject always to Articles 14.5
and 14.7.
(c) CEPA shall cause the Bond and the O & M Bond to be maintained in
force and effect in the applicable amounts set forth above until the
Completion Date and Transfer Date, respectively. For such purpose,
CEPA shall ensure that, on a timely basis, (i) the amount available
under the Bond is increased when required under paragraph (a) above,
and (ii) the Bond (if expiring by its terms before the Completion
Date) and the O & M Bond (if expiring by its terms before Transfer
Date) are extended, renewed or replaced at least fifteen (15) days
before their respective expiry dates, in each case for a term not
shorter than six (6) calendar months.
ARTICLE 4
TESTING
4.1 TESTING PROCEDURES. The parties shall meet and agree on procedures,
standards, protective settings and a program to be followed by CEPA for
the testing of the Units and the Power
18
24
Station in accordance with the Thirteenth Schedule (Test and
Inspection) and NPC undertakes to take all electricity generated
during any such testing and to pay an amount equal to the Energy Fees
for the energy delivered to the system. For such purpose, the Unit Net
Heat Rate shall be the guaranteed Net Heat Rate for the Unit.
4.2 COAL. All coal used in the testing of the Units and the Power Station
shall be Performance Coal.
4.3 NOTICE OF TESTING. CEPA shall give to NPC not less than fourteen (14)
days' notice, or such lesser period as the parties hereto may agree,
of its intention to commence any testing at the Site.
4.4 NPC'S RESPONSIBILITIES. NPC shall ensure that there is made available,
at its own cost, for any testing supplies of Fuel in sufficient
quantity for the proper carrying out of such testing and of the
quality specified in the Schedules hereto.
4.5 COST OF UTILITIES. The cost of the Fuel to be supplied by NPC pursuant
to Article 4.4 shall be for NPC's account, however, the cost of Fuel
for no-load tests shall be for the account of CEPA.
4.6 ATTENDANCE AT TESTING. NPC and/or its experts shall be entitled to be
present at any testing at the Site; Provided notice has been given
pursuant to Article 4.3, tests may be conducted validly at the
notified times in the absence of representatives of NPC.
4.7 CERTIFICATION. Forthwith upon the completion of any testing, CEPA
shall certify whether or not an Unit or the Power Station has
satisfied such test and shall provide NPC with a copy of such
certificate Provided that the certification by CEPA as to the results
of the guarantee tests to demonstrate Nominated Capacity and Unit Net
Heat Rate pursuant to Section 4 of the Thirteenth Schedule (Test and
Inspection) shall be subject to the written confirmation of NPC (which
confirmation NPC shall not unreasonably withhold).
4.8 OPTIONAL TESTS. Should an Unit exhibit unusually high Fuel consumption
in relation to its power output, NPC may, upon fourteen (14) days'
notice and subject to the availability of Performance Coal, require
CEPA to test such Unit for its Unit Net Heat Rate in accordance with
the procedures set out in Section 4 of the Thirteenth Schedule (Test
and Inspection), provided such test shall be conducted not more often
than once in any year. In the event that the test shows an Unit Net
Heat Rate higher than the Unit Net Heat Rate guaranteed for the year
following the year in which the test is conducted, as provided in
Section 6 of the Second Schedule (Operating Parameters), the Unit Net
Heat Rate for the Unit following such test
19
25
shall be the Unit Net Heat Rate proven at the test, until such time as CEPA
shall be able to prove, through a similar test, a lower Unit Net Heat Rate, and
(i) the cost of electricity for start-up of the Unit following any shutdown for
such test shall be for the account of CEPA, and (ii) the number of days of
allowed Unplanned Outage shall not be increased by the number of days of such
shutdown.
ARTICLE 5
OPERATION OF THE POWER STATION
5.1 CEPA'S RESPONSIBILITIES. CEPA shall, at its own cost, be responsible
for the management, operation, maintenance, including the supply of
consumable and spare parts, and repair of the Power Station until the
Transfer Date and shall use its best endeavours to ensure that during
such period the Power Station is in good operating condition and
capable of converting Fuel supplied by NPC into electricity in a safe
and stable manner within the Operating Parameters. CEPA shall be
responsible for the maintenance of the (i) Access Road from and to the
National Highway and the Site and the Ash Disposal Sites and all
intrasite roads within the Power Station and (ii) the Pipelines,
should the same be constructed. CEPA shall also maintain good
relationship with the local community throughout the Cooperation
Period.
5.2 PLANNED OUTAGE. Notwithstanding Article 5.1, it is understood and
agreed by NPC and CEPA that in order to undertake necessary overhaul,
maintenance, inspection and repair CEPA shall be entitled to periods
of Planned Outage as provided in the Sixth Schedule (Electricity
Delivery Procedures). By not later than the Completion Date of Unit I
and each anniversary thereof, the parties hereto shall agree an annual
schedule for Planned Outage during the course of the succeeding year
which shall be revised as provided in the Sixth Schedule (Electricity
Delivery Schedule). CEPA shall notify NPC immediately upon the
occurrence of any Unplanned Outage and provide its best estimate of
the probable duration of such outage.
5.3 OPERATION. CEPA undertakes that until the Transfer Date, subject to
the supply of the necessary Fuel pursuant to Article 6 and to the
other provisions hereof, it will operate the Power Station to convert
such Fuel into electricity in accordance with Article 7.
5.4 CEPA's RIGHTS. In pursuance of its obligations under Article 5.1, CEPA
shall, amongst other things, have full right to:
(i) enter into contracts for the supply of materials and
services, including, contracts with NPC;
20
26
(ii) appoint and remove consultants and professional
advisers;
(iii) purchase replacement equipment;
(iv) appoint, organize and direct staff, manage and
supervise the Power Station;
(v) establish and maintain regular inspection,
maintenance and overhaul procedures;
(vi) maintain and repair the Access Road; and
(vii) do all other things necessary or desirable for the
running of the Power Station within the Operating
Parameters.
5.5 NPC'S OBLIGATIONS. NPC shall at its own cost:
(i) maintain and repair the Transmission Line to ensure
that at all times it is capable of operating within
the specifications set out in the Fifth Schedule
(Transmission Line Specifications); and
(ii) ensure that CEPA retains complete possession of the
Site and the Ash Disposal Sites and use of the
Access Road and the Pipelines on a continuing and
uninterrupted basis as well as all land from time to
time required in connection with the construction,
installation, use, repair and maintenance thereof.
5.6 SAFETY AND TECHNICAL GUIDELINES. NPC and CEPA shall organize a
steering committee which shall, from time to time, meet and discuss
and agree safety and technical guidelines for the operation of the
Power Station within the Operating Parameters and NPC'S system
requirements and following such agreement CEPA shall operate the Power
Station within such safety and technical guidelines.
5.7 AVAILABILITY. Availability will be determined by reference to Planned
Outage calculated as provided in the Sixth Schedule (Electricity
Delivery Procedures) and the parties hereto will agree an annual
schedule of availability which shall be reviewed from time to time
taking into consideration the requirements of both parties hereto; in
agreeing the Availability Schedule, CEPA shall take account of the
requirements of NPC.
21
27
5.8 ENVIRONMENTAL IMPACT. CEPA shall monitor and produce reports on the
environmental impact of the Power Station in accordance with the
requirements of the Environmental Compliance Certificate and shall
operate the Power Station in the compliance with the requirements of
the Environmental Compliance Certificate.
5.9 MEASUREMENT. Measurement of Coal usage during operation will be by
coal weigher integrators installed at the coal feeders. Measurement of
Oil usage during operation will be by flow meters of a type acceptable
to NPC and CEPA with integrators installed between the oil storage
tanks and the oil burners.
5.10 FLY ASH. NPC may, at its option and cost, take delivery of and remove
fly ash produced by the Power Station without obligation to pay for
the same, provided that CEPA's only obligation shall be to make the
same available for receipt by bulk carriers at the fly ash silos
chutes at the Site. CEPA shall be free to dispose of fly ash at the
Ash Disposal Sites or otherwise for its account if NPC does not give
CEPA timely notice of NPC's desire to acquire the fly ash or, having
given such notice, NPC fails to remove such fly ash on a timely basis.
NPC shall indemnify and hold CEPA free and harmless from and against
any costs, expenses, damages, suits or claims arising from the
taking, use or sale by NPC of fly ash or its application for any
purpose whatsoever after receipt by NPC.
ARTICLE 6
SUPPLY OR FUEL
6.1 SUPPLY OF FUEL. Throughout the period from the testing and
commissioning of Unit 1 until the Transfer Date, NPC shall at all
times supply and deliver, at its own cost, Fuel required by CEPA and
necessary for the Power Station to generate the electricity required
to be produced by it pursuant to Article 7.
6.2 DELIVERY. NPC shall ensure that at all times the necessary stocks of
Fuel as required by CEPA are delivered and stored at the Site or are
available for immediate delivery to the Site. CEPA shall submit to NPC
monthly projection of Coal and Oil usage for one (1) year. NPC and
CEPA will liaise to prepare Fuel schedules showing anticipated times
and quantities of Fuel to be utilized by the Power Station, and NPC
shall be responsible for ensuring the availability of Fuel supplies,
for the payment therefor and for all arrangements with the suppliers.
Delivery to the Power Station will be arranged and paid for by NPC,
and, in respect of Coal, will be by sea to the Jetty at the Site and,
in respect of Oil, will be by road and sea to the oil delivery points
identified as such by CEPA and then by pipeline to the oil storage
tanks at the Site. CEPA will be responsible for unloading, stacking
out and
22
28
reclaiming Coal to and from the coal stockpile on the Site. NPC and
CEPA shall agree on procedures for the measurement of the volume of
Fuel delivered to CEPA, which procedures shall be set out in the fuel
management agreement referred to in Article 6.7.
6.3 COST. Without prejudice to Article 4.5, the cost of the Fuel to be
supplied by NPC pursuant to Article 6.1 shall be for NPC's account.
6.4 QUALITY DETERMINATION.
(a) NPC shall, before shipment, cause coal samples representative
of the shipment to be taken in accordance with ASTM standards
and procedures and analyzed by a qualified independent
testing laboratory appointed by NPC. CEPA may assign
representatives to observe and witness the aforesaid
samplings and analyses at its own cost. NPC shall provide
CEPA with certificates of analysis. The costs and expenses
for such coal testings and analyses will be for the account
of NPC.
(b) Upon delivery to CEPA at the Site, all fuel oil and coal
shall be tested for compliance with the Fuel Specifications
at a laboratory and in accordance with sampling and test
procedures and fuel analysis parameters agreed upon by CEPA
and NPC and set out in the fuel management agreement referred
to in Article 6.7. Should a party disagree with the results
of any test conducted pursuant to this subparagraph (b), such
party may, at its own cost, have the fuel oil and coal
re-tested by a qualified independent testing laboratory
acceptable to both parties.
(c) CEPA shall, at all times, be entitled to reject, and NPC
shall then remove at NPC's cost, any fuel oil and coal if the
results of any test relating to it show that it does not
comply with the Fuel Specifications but NPC shall not have
liability to CEPA for damage to the Power Station resulting
from fuel oil and coal not complying with Fuel
Specifications.
6.5 STORAGE, CUSTODY AND SECURITY. Coal delivered to the Site shall be
stored at the coal stockpile at the Site. Oil delivered to the Site
shall be stored in the oil storage tanks erected by CEPA. CEPA shall
be responsible for all security, insurance and safety arrangement in
respect of all Fuel delivered and turned over by NPC to CEPA at the
Site in accordance with the terms of a fuel management agreement to
be entered into pursuant to Article 6.7.
6.6 INSURANCE. Subject to Article 6.7, NPC shall be responsible for and
shall bear the risk of damage to or loss of the Fuel, for whatever
reason, at all times prior to the Fuel being consumed by CEPA for the
purpose of converting such Fuel into electricity pursuant to the
23
29
terms hereof. NPC shall ensure that at all such times prior to
delivery to CEPA at the Site the Fuel is insured for full
reinstatement value with a reputable insurance company against such
loss or damage. CEPA shall ensure that all such Fuel delivered and
received by it at Site is insured for full reinstatement value with
reputable insurance company against any loss or damage.
6.7 FUEL MANAGEMENT. Following the delivery and receipt thereof, CEPA
shall manage the stocks of Fuel and shall ensure the safe storage
thereof in accordance with the standards of a prudent operator of a
plant such as the Power Station and, to the extent not covered by any
policy of insurance issued pursuant to the terms hereof, CEPA shall be
responsible for any loss of Fuel caused as a direct consequence of its
gross negligence or wilful misconduct or that of its agents or
authorized representatives. NPC and CEPA shall as soon as possible
after the date hereof negotiate in good faith with the view to
executing not later than six (6) months from date hereof a fuel
management agreement setting out the implementing details for the
delivery, measurement, analysis, storage, custody, inventory and
security of Fuel to be provided by NPC to CEPA pursuant to and upon
the terms set out in this Agreement.
ARTICLE 7
SUPPLY OF ELECTRICITY, FEES AND FOREIGN EXCHANGE
7.1 SUPPLY. Subject to NPC supplying the necessary Fuel and electricity
pursuant to the provisions of this Agreement, CEPA agrees to convert
such Fuel into electricity and NPC agrees to take and pay for all
electricity requested by NPC in accordance with the procedures set out
in the Sixth Schedule (Electricity Delivery Procedures) and the
Operating Parameters set out in the Second Schedule (Operating
Parameters). CEPA shall dedicate the entire Power Station output (net
of Power Station usage) to NPC.
7.2 QUANTITY. The quantities of electricity delivered to NPC by CEPA from
time to time shall be monitored, measured and recorded in accordance
with provisions of the Seventh Schedule (Measurement and Recording of
Electricity).
7.3 FAILURE TO SUPPLY/ACCEPT ELECTRICITY. CEPA shall notify NPC promptly
of the occurrence of any event (other than Planned Outage) which
results or may result in the Power Station being unable to operate in
accordance with the Specifications and within the Operating Parameters
and NPC shall notify CEPA promptly of the occurrence of any event
which results or may result in NPC being unable to accept electricity
in accordance with the requirements previously notified to CEPA.
24
30
7.4 DELIVERY OF ELECTRICITY. The place for delivery of the electricity
shall be the Delivery Points. Without prejudice to the provisions of
Article 7.5 and NPC's obligations to make payments, it is acknowledged
that the Power Station is a dispatchable provider of electricity and
accordingly, subject to NPC giving the necessary notice, NPC shall
only be obliged to accept power that it has requested.
7.5 FEES
(a) Save as provided in sub-paragraph (b) below, in respect of
each Month, or part thereof, falling within the Cooperation
Period in respect of each Unit, NPC shall pay to CEPA Capital
Recovery Fees, Fixed Operating Fees, Service Fees,
Infrastructure Fees and Energy Fees in each case calculated
as provided in the Eighth Schedule (Delivery of Power and
Energy).
(b) Without prejudice to the operation of Article 3.16, if the
Unit Completion Date in respect of an Unit occurs prior to
the commencement of its Cooperation Period then, for the
period commencing on such Unit Completion Date and ending on
the day falling immediately prior to the first day of such
Cooperation Period, and also for the period commencing
twenty-five (25) years after such Unit Completion Date, and
ending on the last day of such Cooperation Period, NPC shall
pay to CEPA by way of fees under this Article only the
amounts pertaining to Fixed Operating Fees and Energy Fees,
in each case calculated as provided in the Eighth Schedule
(Delivery of Power and Energy).
(c) After the end of the Cooperation Period in respect of the
first Unit, NPC will make payments on the same basis as
provided in sub-paragraph (b) above in respect of electricity
which CEPA certifies is available to NPC from such Unit.
7.6 INVOICES FOR FEES. In respect of each Month, CEPA will deliver to NPC
an invoice in respect of Capital Recovery Fees, Fixed Operating Fees,
Service Fees, Infrastructure Fees and Energy Fees for such Month and
NPC shall pay to CEPA the amount of such invoice within thirty
(30) days after the delivery of such invoice.
7.7 PAYMENT. All fees payable to CEPA pursuant to this Article 7 shall be
paid in the currencies stipulated in the Eighth Schedule (Delivery of
Power and Energy) save that any value added tax thereon (which shall
be separately stated in all invoices) shall be paid in pesos and each
sum payable shall be increased so as to ensure that after NPC has
deducted therefrom any and all taxes or charges required to be
deducted therefrom pursuant to Article 7.11 by NPC there
25
31
remains a sum equal to the amount that would have been payable to CEPA
had there been no requirement to deduct or withhold such taxes or
other charges.
7.8 PRE-COMPLETION ENERGY FEES. During commissioning and testing, NPC
shall pay to CEPA Energy Fees calculated as provided in the Eighth
Schedule (Delivery of Power and Energy) in respect of all electricity
generated. For such purpose, the Unit Net Heat Rate for each Unit
shall be its guaranteed Unit Net Heat Rate.
7.9 PRE-COMPLETION AND STANDBY FEES. Subject to Article 13, NPC shall pay
CEPA pre-completion and standby fees equal to the Service Fees and 50%
of the Fixed Operating Fees calculated as provided in the Eighth
Schedule (Delivery of Power and Energy) on the basis that the Unit or
Units shall be deemed to have been successfully tested to their Net
Contracted Capacity, in respect of the period, if any, from the date
upon which CEPA provides notice of its intention to commence testing
following mechanical and electrical completion of one or both of the
Units until the date upon which NPC confirms that installation and
connection of the Transmission Line have been completed and that it is
capable of operating within the specifications contained in the Fifth
Schedule (Transmission Line Specifications).
7.10 INVOICES FOR PRE-COMPLETION AND STANDBY FEES. In respect of each
calendar month or part thereof, CEPA will deliver to NPC as invoice in
respect of the fees payable pursuant to Articles 7.8 and 7.9 for such
month and any bonus or fees payable hereunder for such month or part
thereof and NPC shall pay to CEPA, the amount of such invoice within
thirty (30) days after the delivery of such invoice.
7.11 NO SET OFF. All payments made by NPC hereunder shall be made free and
clear of and without deduction for or on account of any set-off,
counterclaim, tax or otherwise except as required by the law of the
Republic of the Philippines.
7.12 DISPUTES. If NPC disputes the amount specified in any invoice it shall
so inform CEPA within fourteen (14) days of receipt of such invoice;
if the dispute is not resolved by the due date NPC shall pay the
undisputed amount on or before such date and the disputed amount
shall be resolved within fourteen (14) days after the due date of such
invoice and all or any part of the disputed amount paid to CEPA shall
be paid together with interest pursuant to Article 29.1 from the due
date of such invoice.
7.13 DOLLAR PAYMENTS. All sums payable to CEPA in dollars shall be payable
in dollars, in same-day fund not later than 11:00 a.m. (time of the
place where the account is located) on the day when the payment is
due, to the account of CEPA with (i) a bank in Hong Kong,
26
32
London or New York which CEPA shall specify or (ii) such other bank
which CEPA shall specify and is acceptable to NPC.
7.14 COST OF PAYMENT. Any costs incurred by NPC in connection with the
remittance of funds outside the Philippines shall be for NPC's account
and NPC shall ensure that the amount received by CEPA shall be the
full gross amount free from any claims or deductions whatsoever
Provided that the portion of any regular and generally applicable bank
charges and fees in excess of 1.50% of the amount remitted shall be
for the account of CEPA and shall be deducted from the amount so
remitted.
7.15 PESO PAYMENTS. All sums payable to CEPA in pesos shall be payable in
pesos in Manila, in same-day funds not later than 11:00 a.m., Manila
time, on the day when payment is due, to the account of CEPA with a
bank in Manila that CEPA shall specify to NPC.
7.16 DOLLAR DEFICIENCY. In the event that any payment, whether pursuant to
judgment or otherwise, upon prompt conversion to dollars and transfer,
as provided in Article 7.13, does not result in payment of the dollar
amount stipulated in this Agreement, CEPA shall be entitled to
immediate payment of, and shall have a separate cause of action for,
the dollar deficiency. However, should any such payment (upon
conversion to dollars and transfer offshore as aforesaid) result in
the receipt by CEPA of a sum in excess of the dollar amount stipulated
in this Agreement, CEPA shall notify and pay the excess amount to NPC
immediately upon CEPA's receipt of notice of the over-payment and its
agreement to the same.
7.17 PAYMENT TO NPC. All sums payable by CEPA to NPC, whether pursuant to
judgment or otherwise, shall be payable in same-day funds not later
than 11:00 a.m., Manila time, on the day when payment is due, to the
account of NPC with a bank in Manila that NPC shall specify.
7.18 CHANGE IN CIRCUMSTANCES. In the event that as a result of any laws or
regulations of the Republic of the Philippines, or any agency or other
body under the control of the Government of the Republic of the
Philippines or any regional or municipal authority thereof, coming to
effect after 14th January, 1994, or as a result of any such laws or
regulations (including any official interpretation thereof which CEPA
has relied upon in entering into this Agreement) in force at the date
hereof being amended, modified or repealed, the interest of CEPA in
the Site, any of the Ash Disposal Sites and Pipelines, the Project or
the Power Station and/or CEPA's economic return (net of tax or other
imposition, including, without limitation any withholding or
remittance tax on the payment of dividends) on its investment is
materially reduced, prejudiced or otherwise adversely affected
(including, without limitation, any
27
33
restriction on the ability to remit funds in foreign currency outside
the Philippines) then parties hereto shall meet and endeavour to agree
amendments to this Agreement and if after ninety (90) days no such
agreement has been reached the provisions of Article 9.5 shall apply.
7.19 DEEMED COMPLETION. If Unit Completion Date is achieved for a Unit on
the basis that such Unit would have successfully completed its testing
had NPC performed its obligations under this Agreement relating to the
Site, the Ash Disposal Sites, the Pipelines and the Access Road, Fuel
and electricity for testing and commissioning and start-up of the
Power Station, and the taking of electricity and the Transmission Line
in a timely manner, the Nominated Capacity for such Unit shall be its
Net Contracted Capacity and its Unit Net Heat Rate shall be its
guaranteed Unit Net Heat Rate, until such time as a guarantee test to
demonstrate Nominated Capacity and Unit Net Heat Rate can be conducted
in accordance with Section 4 of the Thirteenth Schedule.
ARTICLE 8
TRANSFER OF OWNERSHIP AND BUYOUT
8.1 TRANSFER. Six (6) calendar months prior to the Transfer Date, CEPA
shall arrange the training at the Site for an adequate number of NPC
personnel in relation to the operation of the Power Station. On the
Transfer Date, CEPA shall transfer to NPC (and shall execute such
documents as may reasonably be considered necessary to effect such
transfer), free from any lien or encumbrance created by CEPA and
without the payment of any compensation, all its right, title and
interest in and to the fixtures, fittings, spare parts, plant and
equipment (including test equipment and special tools and vehicles
used solely in plant management and operation) and all improvements
comprising the Power Station. CEPA shall also deliver to NPC on such
date such operating manuals, operation summaries/transfer notes,
design drawings, including any revision to "as-built" plans to reflect
improvements, additions or other changes introduced to the Power
Station during the Cooperation Period, and other information as may
reasonably be required by NPC to enable it to take over the operation
of the Power Station. CEPA shall arrange a maintenance schedule which
ensures that a scheduled overhaul (at which an agreed number of NPC
personnel may be present at NPC's cost) of the Power Station shall
occur within twelve (12) calendar months of the Transfer Date. NPC
acknowledges and agrees that ownership of the Jetty may have to be
turned over to the Philippine Ports Authority on or before the
Transfer Date in accordance with the regulations issued by such
Authority.
28
34
8.2 INVENTORIES. Six (6) calendar months prior to the Transfer Date, NPC
and CEPA shall meet and agree the inventories involved, the mechanics
of transfer and security arrangements but CEPA shall not be liable for
any discrepancies between such inventories and and the actual
fixtures, fittings, plant and equipment and vehicles transferred
provided that following agreement on inventories CEPA shall exercise
the same care regarding the fixtures, fittings, plant and equipment
and all improvements therein as it did prior to agreeing the same and
provided further that NPC shall be entitled to provide a security unit
within the Site.
8.3 WARRANTIES. The Power Station and all other equipment transferred
pursuant to Article 8.1 or otherwise pursuant to this Agreement shall
be transferred on an "as is" basis and any warranties which would
otherwise be implied by statute or otherwise, including, without
limitation, warranties as to title, fitness for the purpose, the
absence of patent or inherent defects, description or otherwise of
whatsoever nature will be excluded and after the Transfer Date CEPA
shall be under no liability whatsoever to NPC or a person designated by
NPC and NPC shall indemnify and keep indemnified CEPA against any
liability to any person arising from the use of operation of the Power
Station after the Transfer Date Provided however that CEPA shall,
subject to the cost of such subrogation or assignment being met by NPC,
subrogate or assign to NPC any and all rights and benefits which it is
able to subrogate or assign of any unexpired warranties in respect of
the building, plant and equipment of the Power Station under applicable
laws or otherwise.
8.4 NPC'S RESPONSIBILITIES. NPC shall be responsible for all costs and
expenses (including legal fees and taxes or duties) incurred in
connection with the transfer referred to in Article 8.1 and shall at
its own cost obtain or effect all governmental and other approvals,
licences, registrations and filings and take such other actions as may
be necessary for the transfer contemplated in Article 8.1, and
reimburse CEPA on demand for all such costs and expenses incurred by
CEPA in respect of such transfer. Except for the preparation of
training programs and the provision of trainers, training materials, a
classroom (if needed) within the Site and transportation within the
Site (which shall be CEPA's responsibility and for its account), NPC
shall (i) be responsible for all arrangements and costs for the
training of its personnel or their attendances at the scheduled
overhaul referred to in Article 8.1, including their transportation,
insurance, board and lodging and (ii) be responsible for all acts and
omissions of its personnel while such personnel are within the premises
of the Power Station.
8.5 BUYOUT. If the circumstances set out in Articles 3.12, 7.18, 9.4, 14.4,
14.5, or 28.3 arise or if, not earlier than twenty (20) years after the
Completion Date, NPC gives not less than ninety (90) days notice to
CEPA that it wishes to close the Power Station or, if NPC has failed to
ensure the due payment of any sum due hereunder within three (3)
calendar months of its due date then, upon CEPA giving to NPC not less
than ninety (90) days notice
29
35
requiring NPC to buy out CEPA or, as the case may be, NPC giving not
less than ninety (90) days notice requiring CEPA to sell out to NPC,
NPC shall purchase all CEPA's right, title, and interest in and to the
Power Station and thereupon all CEPA's obligations hereunder shall
cease. Upon the earlier of such purchase and the expiry of any such
ninety (90) days notice period, CEPA shall be released from all of its
obligations under this Agreement.
8.6 WARRANTIES AND RESPONSIBILITIES. In respect of any transfer of the
Power Station pursuant to Article 8.5, the provisions of Articles 8.3
and 8.4 shall apply thereto and the Power Station shall be transferred
free from any lien or encumbrance created by CEPA.
8.7 BUYOUT PRICE. Subject to Article 8.8, the purchase price in dollars,
payable pursuant to Article 8.5, will be the total remaining amount of
the Capacity Fees (except Fixed Operating Fees) payable to CEPA
pursuant to Article 7.5 until the transfer Date upon the assumption
that the Nominated Capacity during each year of the Cooperation Period
for such period is equal to the lower of the Nominated Capacity last
nominated by CEPA and the Net Contracted Capacity and the resulting
figure discounted to its value on the date of completion of the
buyout by applying a discount rate equal to the last published
Commercial Interest Reference Rate for dollars by the Organization for
Economic Cooperation and Development Provided that no buyout may take
place without the consent of CEPA if the purchase price calculated as
above is not positive Provided further that if NPC is to buy out CEPA
pursuant to Article 8.5 pursuant to a notice given by NPC not earlier
than twenty (20) years after the Completion Date that NPC wishes to
close the Power Station in calculating the purchase price pursuant to
this Article the Service Fees shall be reduced by five per cent (5%).
8.8 PRE-COMPLETION BUYOUT PRICE. If the provisions of Article 8.5 apply
prior to the Completion Date, the purchase price payable shall be an
amount equal to the aggregate of all the costs, expenses and
liabilities incurred by CEPA in connection herewith as estimated by an
independent accountant jointly appointed by both parties plus an
amount equal to ten per cent (10%) or such aggregate provided such
additional amount shall not be payable if the provisions of Article
8.5 are applicable pursuant to Article 14.4.
8.9 TIMING. Completion of a buyout pursuant to Article 8.5 shall take
place on the date of the expiry of the notice specified therein at
which time NPC will pay CEPA the purchase price calculated in
accordance with Article 8.7 or, as the case may be, Article 8.8 and
payable in dollars and CEPA shall warrant that following such buyout
the Power Station shall be free from any lien or encumbrance created
by CEPA.
8.10 DEDUCTIONS. In the event that the provisions of Article 8.5 apply
pursuant to Article 14.4 or 14.5 then there shall be deducted from
the sum payable pursuant to Article 8.7 or 8.8 an
30
36
amount equal to the value, if any, of any insurance proceeds received
by CEPA in respect of the event leading to the operation of the
provisions of Article 14.4 or 14.5.
ARTICLE 9
REPRESENTATIONS AND WARRANTIES OF CEPA
9.1 CORPORATE EXISTENCE. CEPA represents that it is a private corporation,
duly organized and existing under the laws of the British Virgin
Islands with the corporate power and authority to execute, deliver and
perform the terms and conditions to be performed by it under this
Agreement and is a wholly-owned subsidiary of Consolidated Electric
Power Asia Limited.
9.2 GOVERNMENT AUTHORIZATIONS. CEPA represents and warrants that it has
taken all necessary corporate action and secured or caused to be
secured (to the extent that the same may reasonably be secured as at
the date hereof) all orders, consents, approvals, licenses and permits
of all relevant governments or governmental agencies in order for it to
construct, own and operate the Power Station.
9.3 COMPLIANCE WITH STANDARDS. CEPA warrants that the Power Station shall
be constructed, operated and maintained in accordance with
internationally accepted engineering standards in force in the
Philippines.
9.4 COMPLIANCE WITH LAWS. CEPA shall operate the Power Station in
accordance with all environmental and other Philippine and local laws
and regulations in force as at 14th January 1994 and shall comply with
any changes in such law and regulations and with any new laws and
regulations provided that if to comply with such change or new laws
and regulations would:
(i) result in the Power Station being unable to operate in
accordance with the Specifications or within the Operating
Parameters; or
(ii) result in the interest of CEPA in the Site, any of the Ash
Disposal Sites and the Pipelines, the Project or the Power
Station and/or CEPA's expectation of its economic return
(net of tax or other imposition) on its investment being
materially and adversely affected,
then the parties shall meet and endeavour to agree on amendments to this
Agreement and if after ninety (90) days no such agreement has been reached the
provisions of Article 8.5 shall apply.
31
37
9.5 WARRANTY AGAINST CORRUPTION. CEPA hereby warrants that neither it nor
its representatives have offered any government officer and/or NPC
official and employee any consideration or commission for this
Agreement nor has it or its representatives exerted or utilized any
corrupt or unlawful influence to secure or solicit this Agreement for
any consideration or commission; that CEPA shall not subcontract any
portion or portions of its scope of the work under this Agreement
awarded to any person known by CEPA to be an official or employee of
NPC or to the relatives within the third degree of consanguinity or
affinity of NPC officials who are directly or indirectly involved in
contract awards or project prosecutions and that if any commission is
being paid to a private person, CEPA shall disclose the name of the
person and the amount being paid and that any material violation of
this warranty shall constitute a sufficient ground for the rescission
or cancellation of this Agreement or the deduction from the contract
price of the consideration or commission paid without prejudice to the
filing of civil or criminal action under the Anti-Graft Law and other
applicable laws against CEPA and/or its representatives and NPC
officials and employees.
ARTICLE 10
REPRESENTATIONS AND WARRANTIES OF NPC
10.1 CORPORATE EXISTENCE. NPC represents that it is a corporation duly
organized and existing under and by virtue of the laws of the Republic
of the Philippines, and has the corporate power and authority to
execute, deliver and carry out the terms and conditions of this
Agreement.
10.2 GOVERNMENT AUTHORIZATIONS. NPC represents and warrants that it has
taken all necessary corporate action, and has secured or caused to be
secured all necessary Government orders, consents or approvals, permit
and licences to enter into this Agreement, purchase power from CEPA
and make payments therefor in the respective currencies referred to
herein except to the extent that a waiver has been obtained in
accordance with Article 28.4.
10.3 COMPLIANCE WITH LAWS. NPC shall, it all times, conform to all laws,
rules, regulations and ordinances applicable to NPC, the failure to
comply with which will have a material adverse effect on its ability
to perform its obligations hereunder.
32
38
ARTICLE 11
TAXES
11.1 TAX RESPONSIBILITIES. NPC shall be responsible for the payment of (i)
all taxes, import duties, fees, charges and other levies imposed by
the Republic of the Philippines or any agency, instrumentality,
political subdivision or taxing authority thereof or therein to which
CEPA (which term shall include, for the avoidance of doubt, CEPA
PHILIPPINES) may at any time be or become subject in or in relation to
the performance of their obligations under this Agreement (other than
(a) taxes imposed or calculated on the basis of the net income of CEPA
(which term shall include, for the avoidance of doubt, CEPA
PHILIPPINES) and the personal income taxes of its personnel and (b)
construction permit fees, environmental permit fees and other similar
fees and charges and (c) municipal taxes imposed on sub-contractors
of CEPA) and (ii) all real estate taxes and assessments, rates and
other charges in respect of the Site, the Ash Disposal Sites, the
Pipelines, the buildings and improvements thereon, the Infrastructure
and the Power Station.
11.2 PAYMENTS FREE AND CLEAR. Without limiting the generality of the
foregoing Article, all sums payable by NPC hereunder, whether by way
of fees, reimbursement of expenses or taxes, or otherwise shall be
paid in full, without set-off or counterclaim, free of any deductions
and withholdings imposed by the Republic of the Philippines or any
agency, instrumentality, political subdivision or taxing authority
thereof or therein, all of which shall be for the account of NPC. In
the event that NPC is prohibited by law from making payments hereunder
free from deductions or withholdings, then NPC shall pay such
additional amounts to CEPA as may be necessary in order that the
actual amount received after deduction or withholding (and after
payment of any additional taxes or other charges due as a consequence
of the payment of such additional amounts) shall equal the amount that
would have been received if such deduction or withholding were not
required.
ARTICLE 12
INSURANCE
CEPA shall be responsible to ensure that there is effected insurance as
provided in the Ninth Schedule (Insurance) and shall provide NPC with copies of
all policies of insurance effected by it. Subject to Article 14.7 and unless
NPC has failed to perform any of its payment obligations hereunder and such
failure continuing, the proceeds of claims against such insurance, except third
party liability and workmen's compensation insurance, with respect to damage or
other casualty to the Power Station shall be applied by CEPA to the extent
necessary to repair or restore the Power Station to its previous condition.
33
39
ARTICLE 13
TRANSMISSION LINE
NPC shall, at its cost, construct, install and connect the Transmission Line
that will permit it to receive the Net Contracted Capacity from Unit 1 and the
Power Station not later than fifty-three (53) calendar months and fifty-six
(56) calendar months, respectively, from the date hereof in accordance with the
specifications set out in the Fifth Schedule (Transmission Line Specifications).
If the Unit/Power Station completion is anticipated to be earlier than
originally scheduled, NPC and CEPA shall use their best efforts to adjust the
program accordingly.
ARTICLE 14
FORCE MAJEURE
14.1 FORCE MAJEURE. No failure or omission to carry out or observe any of
the terms, provisions or conditions of this Agreement shall give rise
to any claim by any party hereto against any other party hereto, or be
deemed to be a breach of this Agreement if the same shall be caused by
or arise out of:
(a) (other than as referred to in paragraph (b) below), any war,
declared or not or hostilities, or of belligerence, blockade,
revolution, insurrection, riot, public disorder,
expropriation, requisition, confiscation or nationalization,
export or import restriction by any governmental authorities,
closing of harbours, docks, canals, or other assistances to or
adjuncts of the shipping or navigation of or within any place,
rationing or allocation, whether imposed by law, decree or
regulation by, or by compliance of industry at the insistence
of any governmental authority, or fire, earthquake, unusual
flood, volcanic activity, storm, typhoons, lightning, tide
(other than normal tides), tsunamis, perils of the sea,
accidents of navigation or breakdown or injury of vessels,
accidents to harbours, docks, canals, or other assistances to
or adjuncts of shipping or navigation, epidemic, quarantine,
strikes or combination of workmen, lockouts or other labour
disturbances or any other event, matter or thing, wherever
occurring, which shall not be within the reasonable control
of the party affected thereby; or
(b) war, declared or not or hostilities occurring in or
involving the Republic of the Philippines, or of belligerence,
blockade, revolution, insurrection, riot, public disorder,
expropriation, requisition, confiscation or nationalization by
or occurring in or involving the Republic of the Philippines,
export or import restrictions by any governmental, regional or
municipal authorities of or within the Republic of the
34
40
Philippines, closing of harbours, docks, canals, or other
assistances to or adjuncts of the shipping or navigation of or
within the Republic of the Philippines, rationing or
allocation, whether imposed by law, decree or regulation by,
or by compliance of industry at the insistence of, any
governmental authority of or within the Republic of the
Philippines, or any other event, matter or thing, wherever
occurring, which shall be within the reasonable control of NPC
or the government of the Republic of the Philippines or any
agency or regional or municipal authority thereof,
each of the foregoing events, matters or things being called "FORCE
MAJEURE" in this Agreement.
14.2 EXCEPTIONS. Notwithstanding Article 14.1, NPC (i) shall not be entitled
to claim for itself Force Majeure in respect of any Force Majeure
mentioned in sub-paragraph (b) of Article 14.1; and (ii) shall not be
relieved of its obligation to make payments of Capacity Fees, Energy
Fees and other fees as provided in Article 7 by the occurrence of any
Force Majeure mentioned in sub-paragraph (b) of Article 14.1 whether
affecting NPC or CEPA.
14.3 PROCEDURE. The party invoking Force Majeure shall:
(i) notify the other parties as soon as reasonably
possible by telex, letter or facsimile of the nature
of the Force Majeure and the extent to which the
Force Majeure suspends the affected party's
obligations under this Agreement; and
(ii) resume performance of its obligations as soon as
possible after the Force Majeure condition no longer
exists.
14.4 REVISED TIMETABLE. If Force Majeure applies prior to the Completion
Date, the parties will meet to discuss a revised timetable for the
completion of the Project indicating the revised target dates of any
Milestone so affected and the target date for any subsequent Milestone
(including, without limitation, Target Completion Dates), and such
agreed revisions shall be set out in writing. If the effect of the
Force Majeure has applied for a period in excess of one hundred and
eighty (180) days, the parties hereto will meet to discuss the basis
and terms upon which the arrangements set out in this Agreement may be
continued and if the parties are unable to agree on such basis and
terms within thirty (30) days following the expiry of such one hundred
and eighty day period and such Force Majeure is mentioned in
sub-paragraph (b) of Article 14.1, the provisions of Article 8.5 shall
apply.
35
41
14.5 COOPERATION PERIOD. If Force Majeure occurs during the Cooperation
Period, the Cooperation Period shall be extended by a period equal to
that during which the effect of the Force Majeure applies Provided
that (i) if such effect applies for a period in excess of one hundred
and eighty (180) days, the parties hereto will meet to discuss the
basis and terms upon which the arrangements set out in this Agreement
may be continued and (ii) if the parties are unable to agree on such
basis and terms within thirty (30) days following the expiry of such
one hundred and eighty day period and such Force Majeure is mentioned
in sub-paragraph (b) of Article 14.1, the provisions of Article 8.5
shall apply.
14.6 CONSULTATION. The parties hereto will consult with each other and take
all reasonable steps to minimize the losses of either party resulting
from Force Majeure.
14.7 UNINSURED FORCE MAJEURE. If any event of Force Majeure occurs which
causes material damage to the Project or the Power Station and such
event or such damage would not ordinarily be insured against by NPC
then CEPA shall not be obliged to reinstate the Power Station, or, as
the case may be, complete the building of the same, until the parties
hereto have agreed upon the terms for such reinstatement or completion
in a manner which will ensure that CEPA's economic return on its
investment is substantially maintained and not prejudiced in any
material way and NPC agrees that it shall promptly, and in good faith,
enter into discussions with CEPA to reach such agreement.
ARTICLE 15
REIMBURSEMENT AND INDEMNITY
NPC shall reimburse and indemnify CEPA for all actual and direct costs and
expenses incurred by CEPA as a result of the extension of the target date for
any Milestone for reasons other than (i) failure by NPC to obtain the approvals
described in Article 28.4; or (ii) fault of CEPA or (iii) Force Majeure, to the
extent that such costs and expenses cannot be avoided by CEPA through
commercially reasonable means.
36
42
ARTICLE 16
SEVERAL OBLIGATIONS
Except where specifically stated in the Agreement to be otherwise, the duties,
obligations, and liabilities of the parties hereto are intended to be several
and not joint or collective. Nothing contained in this Agreement shall ever be
construed to create an association, trust, partnership, or joint venture among
the parties hereto. Each party hereto shall be liable individually and severally
for its own obligations under this Agreement.
ARTICLE 17
NOTICES
17.1 WRITING. Unless otherwise stated, each communication to be made
hereunder shall be made in writing but, unless otherwise stated, may be
made by telex, letter or facsimile.
17.2 ADDRESSES. Any communication or document to be made or delivered by one
party to another pursuant to this Agreement shall be made or delivered
to the other at the following address, telex number or facsimile
number:
NATIONAL POWER CORPORATION
President
Xxxxx Xxxx xxxxxx Xxxxxx Xxxxxx
Xxxxxx Xxxx, Xxxxxxxxxxx
Telex Number: 40120 NAPOCOR PM
Facsimile Number: (0000) 000-00-00
CEPA PANGASINAN ELECTRIC LIMITED
63rd Floor, Hopewell Centre
000 Xxxxx'x Xxxx Xxxx
Xxxx Xxxx
Facsimile Number: 527-0971
PANGASINAN ELECTRIC CORPORATION
Attention: The President
37
43
Suite 202, CTC Building
0000 Xxxxx Xxxxxxxxx
Xxxxx Xxxx
Xxxxx Xxxxxx
Xxxxxxxxxxx
Facsimile Number: (000) 000 0000
or such other address, telex number or, as the case may be, facsimile number
notified by that party to the other party by giving not less than fifteen (15)
days notice of such change of address or number, and shall be deemed to have
been made or delivered (i) in the case of any communication made by letter, when
left at that address or otherwise received by the addressee (ii) in the case of
any communication made by telex with correct answerback, when despatched to
such telex number and (iii) in the case of any communication made by facsimile,
when a legible copy of such communication has been received.
ARTICLE 18
NON-WAIVER
None of the provision of this Agreement shall be considered waived by either
party except when such waiver is given in writing. The failure of either party
to insist, in any one or more instances, upon strict performance of any of the
provision of this Agreement or to take advantage of any of its rights hereunder
shall not be construed as a waiver of any such provisions or the relinquishment
of any such rights for the future, but the same shall continue and remain in
full force and effect.
ARTICLE 19
BENEFIT OF AGREEMENT
19.1 ASSIGNMENT BY NPC. NPC may not assign or transfer all or any part of
its rights, benefits or obligations hereunder Provided that this
Article shall not prevent NPC from merging or consolidating with any
other company which is wholly or substantially owned by the Republic
of the Philippines where the surviving entity adopts and becomes fully
liable to perform NPC's obligations hereunder and such merger or
consolidation does not affect the validity and enforceability of the
Performance Undertaking.
19.2 ASSIGNMENT BY CEPA. CEPA may not, without the consent of NPC, subject
to Article 19.3, transfer all or any of its obligations hereunder but
may, for the purposes of arranging or
38
44
rearranging finance for the Project, assign or transfer to any person
providing finance to the Project all or any part of its rights and
benefits hereunder but not its obligations and NPC shall duly
acknowledge and consent to any such assignment or transfer of which it
is given notice.
19.3 CEPA PHILIPPINES. The importation into the Philippines of all equipment
for the Project and all other work in connection with the Project which
necessarily has to be performed in the Philippines and which CEPA
agrees to be responsible for hereunder shall be carried out by CEPA
PHILIPPINES, which shall perform CEPA's obligations with respect to
such work and in consideration of which NPC shall pay fees as provided
in Article 7; CEPA PHILIPPINES, in carrying out such work and receiving
such fees, shall act on its own behalf and for its own benefit, and not
as an agent or representative of CEPA; for such purpose, CEPA, NPC and
CEPA PHILIPPINES (whose participation CEPA has procured) shall execute
and deliver the Accession Undertaking on the date hereof, upon the
effectiveness of which CEPA PHILIPPINES shall become a party hereto
without the need for any further action on the part of CEPA or NPC and
the rights or obligations of NPC and CEPA under this Agreement shall be
transferred and amended in accordance with the terms of the Accession
Undertaking, as if CEPA PHILIPPINES had executed this Agreement as
amended by the terms of the Accession Undertaking.
ARTICLE 20
DISPUTE RESOLUTION
20.1 REGULAR MEETINGS. Throughout the term of this Agreement, officials of
NPC and the authorized representatives of CEPA shall meet regularly to
discuss the progress of the Project and the operation of the Power
Station in order to ensure that the arrangements between the parties
hereto proceed on a mutually satisfactory basis.
20.2 AMICABLE SETTLEMENT. The parties hereto agree that in the event that
there is any dispute or difference between them arising out of this
Agreement or in the interpretation of any of the provisions hereof they
shall endeavour to meet together in an effort to resolve such dispute
by discussion between them but, failing such resolution, the Chief
Executives of CEPA and NPC shall meet to resolve such dispute or
difference and the joint decision of such Chief Executives shall be
binding upon the parties hereto and in the event that a settlement of
any such dispute or difference is not reached pursuant to this Article
20 then the provisions of Article 24 shall apply.
39
45
ARTICLE 21
ENTIRE AGREEMENT
This Agreement and its Schedules and figures supersede any previous agreements,
arrangements or representations between the parties, whether oral or written, in
respect of the subject matter hereof and shall constitute the entire agreement
between the parties in relation thereto.
ARTICLE 22
LAW
This Agreement shall governed by and construed in accordance with the laws of
the Republic of the Philippines.
ARTICLE 23
DISCLAIMER
Notwithstanding anything to the contrary in this Agreement, in no event shall
either party be liable to the other party for any indirect, special, incidental,
consequential or exemplary damages with respect to any claim arising out of this
Agreement, whether based upon contract, tort (including negligence), strict
liability, patent, trademark, or servicemark or otherwise.
ARTICLE 24
JURISDICTION
24.1 PHILIPPINE COURTS. The parties hereto submit to the non-exclusive
jurisdiction of the proper courts of Quezon City, Metropolitan Manila,
Philippines for the hearing and determining of any action or proceeding
arising out of or in connection with this Agreement.
24.2 IMMUNITY. To the extent that NPC may in any jurisdiction claim for
itself or its assets or revenues immunity from suit, execution,
attachment (whether in aid of execution, before judgement or otherwise)
or other legal process and to the extent that in any such jurisdiction
there may be attributed to itself or its assets or revenues such
immunity (whether or not claimed) NPC agrees not to claim and
irrevocably waives such immunity to the full extent permitted by the
laws of such jurisdiction.
40
46
ARTICLE 25
EFFECT OF ARTICLE/SECTION HEADINGS
Article, paragraph and/or section headings appearing in this Agreement are
inserted for convenience only and shall not be construed as interpretation of
text.
ARTICLE 26
SEPARABILITY
If any part or parts of this Agreement shall be declared invalid by competent
courts, the other parts hereof shall not thereby be affected or impaired.
ARTICLE 27
LIABILITY
27.1 LIMIT OF LIABILITY. CEPA's liability to NPC arising from any breach of
this Agreement or otherwise in connection with the Power Station shall
be limited to payments as provided in Articles 3.13, 3.14 and 6.7.
27.2 NPC INDEMNIFY. NPC shall indemnify and hold CEPA, its officers and
employees harmless against any claims of any person who directly or
indirectly suffers as a result of an interruption of electricity
supply or any other disruption or surge of electricity supply arising
out of or in connection with this Agreement and any of CEPA's officers
or employees' actions or omissions in connection with the same and NPC
shall indemnify CEPA against any loss, cost or expense resulting from
damage to the Power Station caused or resulting from any interruption
or disruption or surge of electricity along the Transmission Line,
unless and to the extent that such loss, cost or expense would have
been avoided had any safety and protective equipment installed on the
Site by CEPA not failed to operate according to specifications agreed
between NPC and CEPA.
27.3 CROSS INDEMNIFY. Subject to Article 27.1, NPC and CEPA shall each
indemnify, defend, and save harmless the other, its directors,
officers, employees and agents (including but not limited to affiliates
and contractors and their employees) from and against all liabilities,
damages, losses, penalties, claims, demands, suits, costs, expenses
(including reasonable attorney's fees and expenses) and proceedings of
any nature whatsoever for bodily injury (including death) or property
damage (but not economic loss or any other consequential damage) that
result from the performance under this Agreement by or on behalf of
that party (including, with respect to CEPA, the engineering, design,
construction, financing, purchase,
41
47
acquisition, acceptance, delivery, ownership, possession, operation, use,
leasing, maintenance, repair, reconditioning, return, abandonment or other
application or disposition of the Power Station and any fuel, equipment,
materials or supplies used therein, by-products (including steam, waste products
or emissions therefrom), except to the extent that such injury and/or any damage
is attributable to the negligent or intentional act or omission of the party
seeking to be indemnified or its directors, officers, employees, representatives
or agents); in the event such injury or damage results from the joint or
concurrent negligent or intentional act or omission of the parties, each shall
be liable under this indemnification in proportion to its relative degree of
fault.
ARTICLE 28
CONDITIONS PRECEDENT
28.1 CEPA CONDITIONS PRECEDENT. It shall be understood and accepted that
prior to the execution of this Agreement that NPC shall have submitted
to CEPA the following, each in form and substance satisfactory to CEPA,
or that such requirement is waived by CEPA:
(i) a certificate of the Corporate Secretary of NPC
confirming the National Power Board's approval for
the execution, delivery and performance by NPC of
this Agreement, the Accession Undertaking and all
other documents in relation hereto or thereto;
(ii) a legal opinion of NPC's General Legal Counsel in the
form set out in the Twelfth Schedule (Form of Legal
Opinion of NPC's General Legal Counsel);
(iii) copies of endorsements/approvals of the relevant
municipal and provincial governments and the Regional
Development Council for the Site, the Ash Disposal
Sites, and all the land required in connection with
the Access Road and the Pipelines;
(iv) a performance undertaking of the Republic of the
Philippines in respect of NPC's obligations hereunder
duly executed and delivered by the Republic of the
Philippines in the form set out in the Tenth Schedule
(Form of Performance Undertaking) together with
copies of such documents which CEPA consider
necessary to ensure the validity and binding effect
of the Performance Undertaking;
42
48
(v) a legal opinion of the Secretary of Justice of the
Republic of the Philippines as to the validity,
enforceability and binding effect of the Performance
Undertaking in form and substance satisfactory to
CEPA;
(vi) the final approval of this Agreement by the Central
Bank;
(vii) a Certificate of NEDA for the purposes of the Uniform
Currency Act of the Philippines; and
(viii) a letter from NPC to CEPA confirming that CEPA may
enter the Site to conduct (a) preliminary works
thereon for data collection for (1) the preparation
of a feasibility study, (2) the design of the Power
Station, (3) the preparation of all environmental
impact statement, (4) the assessment of land value
and the classification of land within the Site, (5)
the establishment of a temporary jetty, site office
and facilities, (b) other related works including
marine data collection and sampling, flora and fauna
data collection, watertable data collection and
sampling, site survey and investigations, soil
sampling and testing, counting of improvements on the
Site and (c) other such activities in connection with
the construction of the Power Station.
28.2 NPC CONDITIONS PRECEDENT. It shall be understood and accepted that
prior to the execution of this Agreement that CEPA shall have
submitted to NPC the following, each in form and substance satisfactory
to NPC, or that such a requirement is waived by NPC:
(i) copies of the memorandum and articles of association
of CEPA as certified by a director of CEPA in a
manner satisfactory to NPC;
(ii) copies of resolutions adopted by CEPA's board of
directors authorizing the execution, delivery and
performance by CEPA of this Agreement, the Accession
Undertaking and all documents in relation hereto and
thereto certified by a director of CEPA in a manner
satisfactory to NPC;
(iii) copies of the articles of incorporation and by-laws
of CEPA PHILIPPINES, as registered with Security and
Exchange Commission, certified by the company
secretary of CEPA PHILIPPINES in a manner
satisfactory to NPC; and
(iv) the accession undertaking, duly executed by CEPA
PHILIPPINES.
43
49
28.3 FAILURE OF CONDITIONS PRECEDENT. In the event that:-
(i) NPC for any reason is unable to obtain registered
legal title to the Site or any of the Ash Disposal
Sites by the respective dates specified in Article
3.7; or
(ii) any of the opinion of the Secretary of Justice of the
Republic of the Philippines, any endorsement or
approval of any relevant municipal or provincial
government or Regional Development Council, the
Central Bank approval and/or the NEDA certification,
if waived by CEPA as a condition to the execution of
this Agreement, is not available by the date
specified in Article 28.4; or
(iii) the requirements in relation to vacant possession of
the Site and the Ash Disposal Sites as set out in
Article 3.7(i) and (ii) respectively are not
satisfied by the dates specified therein; or
(iv) NPC for any reason fails to provide CEPA with
peaceful and exclusive possession of and access to
the Site, any of the Ash Disposal Sites or any land
required in connection with the construction,
installation, use, repair and maintenance of the
Access Road and the Pipelines when required under the
other provisions of this Agreement; or
(v) the Board of Investments fails to approve the
registration of CEPA PHILIPPINES as a registered
pioneer enterprise under the Omnibus Investments Act
(as the same may be amended from time to time) or any
substitute legislation, within one (1) year from the
date hereof; or
(vi) the registration of CEPA PHILIPPINES as a registered
pioneer enterprise, the Environmental Compliance
Certificate issued for the Power Plant, any approval
issued by the Central Bank necessary for
foreign-currency bridge or other loans by CEPA or any
other person to CEPA PHILIPPINES or for the Financial
Closing, or any of the endorsements, approvals,
consents or registrations referred to in Article 28.1
is subsequently terminated, withdrawn, rescinded or
amended or any new required extension, approval,
consent or registration cannot be obtained on a
timely basis for reasons other than fault of CEPA; or
(vii) any of the consents, licences, permits, approvals and
registrations by or with the Philippine government or
any agency, instrumentality or department or
44
50
political subdivision thereof necessary for the
Project including the construction, operation and
maintenance of the Power Station and the
Infrastructure and the reclamation, occupation and
use of any land required for the Project, cannot be
obtained on a timely basis or is terminated,
withdrawn, rescinded or amended, and any new required
extension, consent, licence, permit, approval or
registration cannot be obtained for reasons other
than fault of CEPA,
and as a result thereof the interest of CEPA in the Site, any of the
Ash Disposal Sites, any land required in connection with the Access
Road or the Pipelines, the Project or the Power Station and/or CEPA's
economic return (net of tax or other imposition) on its investment is
materially reduced, prejudiced or otherwise adversely affected
(including, without limitation, any restriction on the ability to remit
funds in dollars outside of the Philippines), then the parties hereto
shall meet and endeavour to agree on amendments to this Agreement and
if after sixty (60) days no such agreement has been reached the
provisions of Article 8.5 shall apply.
28.4 FURTHER SUBMISSIONS. In the event submissions by NPC of the legal
opinion of the Secretary of Justice of the Republic of the Philippines,
any endorsement or approval of any municipal or provincial government
or Regional Development Council, the Central Bank approval or the
certificate for NEDA required under Article 28.1 is waived as a
condition to the execution of this Agreement, NPC shall obtain such
legal opinion, endorsement, approval or, as the case may be,
certification and submit the same to CEPA not later than a date falling
three (3) calendar months after the date hereof.
ARTICLE 29
LATE PAYMENT
29.1 BY NPC. If any amount payable by NPC hereunder whether in respect of
fees or otherwise and whether pursuant to judgement or otherwise is not
paid on or before the due date NPC shall pay interest thereon,
calculated at the rate of overnight U.S. Federal Funds plus 2% per
annum if the amount was due in dollars, and the T-Xxxx Rate plus 3% per
annum if the amount was due in pesos, from the date upon which it was
due until the date which such amount is received by CEPA.
29.2 BY CEPA. If any amount payable by CEPA, whether pursuant to judgment or
otherwise, is not paid on or before the due date, CEPA shall pay
interest thereon, calculated at the rate of overnight U.S. Federal
Funds plus 2% per annum if the amount was due in dollars, and T-
45
51
Xxxx Rate plus 3% per annum if the amount was due in pesos, from the
date it was due until the date upon which such amount is received by
NPC.
ARTICLE 30
COUNTERPARTS
This Agreement may be executed in any number of counterparts each of
which when executed and delivered shall be an original but all the counterparts
together shall constitute one and the same instrument.
AS WITNESS the hands of the duly authorized representatives of NPC on 29 April
1994 and of CEPA on 1994.
46
52
FIRST SCHEDULE
PROJECT SCOPE AND SPECIFICATIONS
I. SCOPE OF AGREEMENT
CEPA shall be responsible for the design, supply, delivery,
installation, erection and operation including civil works, testing and
commissioning, of a 1,000 MW Coal-Fired Thermal Power Station
consisting of 2 X 500 MW generating units.
II. THE SITE
The plant site ("SITE") is located in Pangascasan, Sual, Pangasinan,
Luzon. Sual is 216 kilometres from Manila. The Site has a land area of
approximately 142 hectares, and is described generally in the site map
attached as Exhibit I hereto. The exact battery limits of the Site will
be agreed by CEPA and NPC not later than two (2) calendar months from
the date hereof.
NPC shall prepare the design and specifications of the Transmission
Line in accordance with NPC's engineering standards and practices as
well as to the operation requirements of the power system.
III. EXTENT OF WORKS/SUPPLY
In pursuance of its obligations under Section I above, CEPA shall be
responsible for, amongst others:
1. STUDIES/PERMITS
(a) Feasibility study;
(b) Environmental Impact Statement (EIS) as required by
the Department of Environmental and Natural Resources
for the issuance of an Environmental Clearance
Certificate (ECC); and
(c) Obtaining the necessary government permits and
clearances for the Project.
47
53
2. CIVIL WORKS
(a) Site development such as grading, gravel surfacing,
construction of roads within the fence, and drainage
facilities, etc.;
(b) Fuel oil and demineralized water tank foundations,
raw water tank including foundation neutralization
pond;
(c) Fly ash silo and related facilities for the
accumulation of ash prior to disposal outside of the
Site;
(d) Switchyard foundations;
(e) Buildings and other structures such as powerhouse,
turbine generator, steam generator and all other
equipment foundations, smokestack, service and
auxiliary buildings, etc.;
(f) Circulating water system and related facilities;
(g) Raw water intake, piping and related structures;
(h) Pilings, as required;
(i) Reclamation of land, as required;
(j) Meteorological tower; and
(k) All other civil works necessary for the Project.
3. INFRASTRUCTURE FACILITIES
(a) Jetty or wharf capable of handling sixty thousand
(60,000) deadweight tonner vessel, unloading
structures and related facilities;
(b) Coal storage yard and related facilities with a
storage capacity sufficient to meet Coal supply
requirements for forty-five (45) days under normal
operating conditions;
48
54
(c) Oil receiving and storage facilities to store fuel
oil required by the Power Station;
(d) Development of Access Road; and
(e) Selection and development of Ash Disposal Sites of an
aggregate size sufficient to hold coal ash produced
by the Power Station during a period of thirty (30)
years.
4. ELECTRO-MECHANICAL WORKS
(a) Boiler island and auxiliaries consisting of steam
generator, pulverized coal system, air ducts and gas
ducts, oil handling equipment, ash handling system,
coal loading and unloading equipment, boiler
feedwater pumps, feedwater booster pumps, boiler
feedwater pumps, water supply equipment, filtered
water equipment, drinking water equipment, house
service water equipment, demineralizer, cycle-water
chemical treatment and waste-water treatment.
Electrostatic precipitator and flue gas
desulphurisation equipment as required to meet
Philippine environmental regulations.
(b) Steam-turbine island consisting of steam-turbine,
condensing equipment, feedwater heaters circulating
water system, chlorinator equipment, bearing cooling
water system, pipe valves, fittings, hangers,
insulation and lagging.
(c) Alternating current equipment and auxiliaries
consisting of generator, excitation system, generator
lead busbar, potential transformer/s and surge
arrester cubicle, power system stabiliser and neutral
grounding device.
(d) Controls such as coal handling control, turbine
generator control, steam generator control,
electrical equipment control and data logging system,
and other instrumentation indicators complete with
the necessary supervisory devices, computers and
protective controls for the Power Station. Complete
line protection at the Power Station side and the
next substation including Power Line Carrier
equipment RTU's, SCADA and recorders.
(e) Power plant mechanical equipment such as turbine room
crane, fire protection equipment, house service air
compressors, instrument air
49
55
compressor, sump pumps, maintenance machines and
machine shop equipment.
(f) Power plant electrical equipment such as main power
and auxiliary transformers, switchyard equipment,
switchgear, motor control centres, alternating
current power supply, direct current power supply
equipment complete with battery charger, emergency
diesel generator, lighting system, paging system,
clock system, meteorological observation equipment,
wiring and tubing, grounding system, and the required
high voltage equipment device, accessories including
necessary cables and hardware for interconnection to
the 230KV switchyard. The switchyard shall be
configured as one and one-half (1 1/2) breaker system
to ensure the reliability and flexibility of the
system interconnection.
(g) Air conditioning system for the protection of
electrical equipment and instruments at the control
room and various offices.
(h) Communication system inside the Power Station and a
microwave communication system compatible with that
of the NPC Power Management Center.
(i) Chemical analysis equipment such as water testing
equipment, coal testing equipment, oil testing
equipment, laboratory glasswares supplies and
chemicals.
(j) Fuel oil system including tanks, pumps, piping system
and metering.
(k) Test instruments, special tools and spare parts.
(1) Motor vehicles for management and operation personnel
and ash disposal transport.
(m) Ash handling and disposal system, including fly ash
silos provided with dustless retractable chutes for
the loading of bulk carriers.
50
56
IV. DESIGN CRITERIA
The Power Station with a Rated Capacity of 2 X 535 MW (100%) shall have
the following characteristics:-
1. RATED CAPACITY
The Rated Capacity of the Power Station shall be the
continuous output at the generator terminal (less excitation
power) with the following conditions:
Steam Pressure at H.P. Turbine: As supplied by CEPA
Steam Temperature at H.P. Turbine: As supplied by CEPA
Steam Temperature at H.P. Turbine: As supplied by CEPA
Opening of all extractions: 100%
Make-up water: 0%
Generator power factor: 0.85
Turbine governing inlet value: Throttling
Circulating water temperature at condenser inlet: 30
(degrees) C
2. MAXIMUM CONTINUOUS RATING
The maximum continuous rating ("MCR") of each Unit measured at
the generator terminal (less excitation power) shall not be
less than 578 MW at 30 deg. C circulating water inlet
temperature.
3. AUTOMATIC CONTROL RANGE
The Power Station shall allow automatic operation control in
the range from 25% of Rated Capacity up to MCR.
51
57
4. MINIMUM OUTPUT
The minimum output at which the Power Station shall be able to
operate under stable conditions shall be 25% of the Rated
Capacity.
5. PLANT OPERATIONAL CHARACTERISTICS
The Power Station shall be designed for the following
operational conditions:
(a) Base load dispatchable operation.
(b) Programmed loading up to an average rate of not less
than 2% of Rated Capacity per minute per Unit with
the Units in the hot condition.
(c) Contribution to the grid frequency control. The Power
Station shall be capable of instantaneous load
variations of not less than 5% of the Rated Capacity
if a Unit has been operated over a sufficient period
under steady conditions. Intervals of 15 minutes are
the minimum necessary between instantaneous load
variations.
6. FUEL
The Fuel specification to be used by CEPA for the design of
the Power Station shall be as provided in the Fourth Schedule.
7. SYSTEM FAULT LEVEL
Projected system fault levels at Labrador Sub-Station shall be
provided by NPC at the design stage.
8. SYSTEM VOLTAGE LEVEL
(a) Generator terminal voltage - Value to be provided by
CEPA
(b) Main Transformer:
High voltage (Nominal) - 230KV
Off Load Tap Change - +/- 5% in 2.5% steps
52
58
Low Voltage - Value to be provided by CEPA
(c) Nominal voltage for auxiliary equipment (for
information purposes):
AC System
Medium Voltage - generation voltage (to be provided
by CEPA) and 13.8KV - 6.6KV, and/or 4.16KV
Low Voltage - 480 and 240V
DC System - 125V, 48V
9. SYSTEM FREQUENCY - 60 HERTZ
10. GENERATOR AND ACCESSORIES
The generator shall be designed to match the steam turbine
unit to assume base operating modes. The design
characteristics shall be as follows:
(a) Nominal apparent power output at rated power: to be
provided by CEPA
(b) Three phase - Wye grounded
(c) Rated terminal voltage: to be provided by CEPA
(d) Rated power factor, lagging - 0.85
(e) Short circuit ratio
The measured value of the short circuit ratio at
rated MVA and rated voltage shall not be less than
0.58.
(f) Allowable voltage variations
At rated MVA, frequency and power factor, the
turbine-generator can operate satisfactorily though
the terminal voltage may vary +/- 5% of rated value.
53
59
11. ELECTRICITY TO BE MADE AVAILABLE BY NPC
Three-phase 230 KV shall be provided by NPC at the terminal
point described in the Fifth Schedule (Transmission Line
Specification).
12. COAL UNLOADER
The continuous type coal unloader shall be sized in accordance
with the following NPC-supplied criteria:
(a) Berth occupancy ratio shall be limited to 60%
considering 80% annual load factor (and 1,000 MW
plant); and
(b) Berth occupancy distribution is 50% for 60,000 DWT
coal carrier, 45% for 30,000 DWT coal carrier and 5%
for 2,500 DWT oil tanker
54
60
SECOND SCHEDULE
OPERATING PARAMETERS
CEPA shall operate the Power Station in accordance with the operating criteria
and guidelines of NPC. CEPA shall cooperate with NPC in establishing emergency
plans including, but not limited to, recovery from a local or widespread
electrical blackout; voltage regulation to effect load curtailment; and other
plans which may arise. CEPA shall operate the Power Station, provide minimum
start-up time and minimum load-carrying ability, as follows:
1. FREQUENCY LIMITATION
The frequency limitation of coal fired power plants for continuous
operation shall be between the range of 57 Hertz and 63 Hertz.
The under frequency tripping relay shall be set at 57.5 Hertz.
2. MAXIMUM CONTINUOUS LOAD OPERATION
The Power Station shall be guaranteed to operate satisfactorily at not
less than 2 X 535 MW at the generator terminal by admitting the maximum
guaranteed throttle flow of the turbine it rated pressure and
temperature with all heaters in service.
3. MINIMUM LOAD OPERATION
The Power Station shall be guaranteed to operate continuously under
automatic control at 25% of the Rated Capacity.
4. RANGE AND RATIO OF LOAD CHANGING
At normal operation, except during start-up and shutdown, the generating
units shall be capable of being generated as follows:
Cold Start to Synchronisation 8 hours
(Off line more than 36 hours)
Warm Start to Synchronisation 6 hours
(Off line 8 to 36 hours)
55
61
Hot Start to Synchronisation 1.5 hours
(Off line 2 to 8 hours)
Very Hot Start to Synchronisation 1 hour
(Off line up to 2 hours)
SYNCHRONISATION AND RAMP LOADING TO FULL LOAD UNDER NORMAL CONDITIONS
(AVERAGE VALUES)
Cold Start-up 0.4%/min
Warm Start-up 0.7%/min
Hot Start-up 2%/min
Very Hot Start-up 2%/min
Note: Percentages refer to Rated Capacity
5. OPERATION MODE
The Power Station shall be utilized as a dispatchable base load plant
and be expected to operate seven (7) days per week.
6. HEAT RATES
The guaranteed Unit Net Heat Rate at Net Contracted Capacity for each
Unit for each successive one-year period, commencing from such Unit's
Unit Completion Date, shall be as follows:
UNIT NET HEAT RATE
(Kcal/KWHR)
--------------------
Year 1 2288
Year 2 2311
Year 3 2334
Year 4 2357
Year 5 2381
Year 6 2330
Year 7 2354
56
62
Year 8 2377
Year 9 2401
Year 10 2425
Year 11 2374
Year 12 2397
Ycar 13 2421
Year 14 2445
Year 15 2470
Year 16 2418
Year 17 2442
Year 18 2466
Year 19 2491
Year 20 2516
Year 21 2462
Year 22 2487
Year 23 2512
Year 24 2537
Year 25 2562
Year 26 2508
Year 27 2533
Year 28 2558
Year 29 2584
Year 30 2610
OPERATING PROCEDURES
1. DISPATCH PROCEDURE
CEPA shall control and operate the Power Station consistent with NPC's
system control and dispatch requirements, provided that (i) the minimum
operating load (other than in Emergency Conditions) of any Unit shall
not be less than 25% of Rated Capacity of each Unit and (ii) during the
initial five (5) years following the Completion Date, NPC shall use its
best endeavours to dispatch the Power Station at a level which will
achieve a monthly average plant capacity factor of not less than
seventy-five per cent (75%) of Net Contracted Capacity.
57
63
2. ENGINEERING STANDARDS
The Power Station including, but not limited to, the protective
apparatus shall be operated and maintained in accordance with good
engineering practices in respect of synchronizing, voltage and reactive
power control.
3. PROTECTIVE DEVICES
The Power Station shall be operated with all of its protective apparatus
in service whenever the facility is connected to or is operated in
parallel with the NPC electric system. Any deviation for brief periods
of emergency or maintenance shall only be by mutual agreement.
4. INTEGRITY LOSS
If, at any time, NPC has reason to doubt the integrity of any CEPA
protective apparatus and suspects that such loss of integrity could
jeopardize the NPC electric system, CEPA shall demonstrate, to NPC's
satisfaction, the correct calibration and operation of the equipment in
question.
5. TESTING AND PROTECTIVE DEVICES
To ensure the safe operation of the Power Station, CEPA shall test all
protective devices with qualified personnel at intervals not to exceed
one (1) year.
6. SERVICE COMMITMENT
At NPC's request, CEPA shall make all reasonable efforts to deliver
power during periods of Emergency.
7. MAINTENANCE DURING EMERGENCY
In the event that CEPA's Planned Outage coincides with an Emergency,
CEPA shall make all reasonable efforts to reschedule the Planned Outage.
8. DAILY OPERATING REPORT FOR RECORD PURPOSES
CEPA shall keep NPC's Power Management Centre informed as to the daily
operating schedule and generation capability of its Power Station,
including, without limitation, to any
58
64
Unplanned Outages and major equipment failure or abnormal operating
condition, either of which are related to power generation failure.
9. OPERATING AND MAINTENANCE RECORDS
CEPA shall maintain the operating and maintenance records for each Unit
with records of real and reactive power production, changes in operating
status, outages, protective apparatus operations and any unusual
conditions found during inspections. Changes in the setting of
protective apparatus shall also be logged. In addition, CEPA shall
maintain records applicable to the Power Station, including the
electrical characteristics of the generator and settings or adjustment
of the generator control equipment and protective devices. Such
information shall be available to NPC upon request.
10. KVAR GENERATION
CEPA shall provide means/devices for generating corrective KVAR for
system voltage regulation consistent with standard utility operation
practices.
59
65
THIRD SCHEDULE
Penalty on Delays
To guarantee the faithful performance by CEPA of its obligation to construct the
Power Station in accordance with the terms and conditions of this Agreement,
CEPA shall post the Bond.
1. DELAY IN ATTAINING CERTAIN INITIAL MILESTONES
In the event that CEPA fails to attain any of the Milestones up to and
including Site Mobilization under the circumstances referred to in
Article 3.13 by a date ("Relevant Date") falling ten (10) days after
the target date for such Milestone calculated and, where applicable,
extended in accordance with the Agreement NPC shall be entitled to draw
on the Bond at the rate of one-thirtieth (1/30) of the maximum amount
then available under the Bond for each day that such Milestone is
delayed after the Relevant Date until the Bond has been fully drawn
upon.
2. DELAY IN COMPLETION
In the event that CEPA fails to complete a Unit as provided in Article
3.13 or 3.14 by the day (the "BOND DAY") falling thirty (30) days after
the Target Completion Date of such Unit, as the same may be extended
pursuant to the Agreement, NPC shall be entitled to draw on the Bond at
the rate of $170,000 for each day that the Target Completion Date of
such Unit is delayed after the Bond Day, until the Bond has been fully
drawn upon.
3. EXHAUSTION OF BOND
In the event that the maximum amount then available under the Bond has
been fully drawn in accordance with Sections 1 and/or 2 above at any
time, CEPA shall have no further liability for delay or failure in the
completion of any Unit or the Power Station.
60
66
FOURTH SCHEDULE
Specifications for Fuel Supply
Specifications
The specifications for the Fuel supply will be as follows:
I. COAL
Australia China Indonesia
------------------------------------------- --------------------- ----------
Item Xxxx "X" "X" "C" "D" "E" "F" "G"
---- --- ------- ------ ------- -------- ------- ------- -------- ----------
Higher Heating Value (as received) HHV Kcal/kg 6,200 6,232 5,960 6,487 6,630 6,165 6,750
Total Moisture (as received) TM % 8.50 9.30 17.40 9.00 9.40 9.67 10.00
Total Sulfur (air dry basis) TS % 1.06 0.50 0.30 0.80 0.70 0.93 0.50
Proximate Analysis (air dry basis)
Inherent Moisture IM % 2.50 2.50 6.30 2.50 4.50 2.73 5.00
Fixed Carbon FC % 55.94 49.65 57.10 53.50 56.50 50.67 52.00
Volatile Matter VM % 24.51 28.85 28.90 31.50 30.60 32.34 38.00
Ash A % 17.05 19.00 7.70 12.50 8.40 14.26 5.00
Total 100 100 100 100 100 100 100
Fuel Ratio 2.30 1.70 2.00 1.70 1.80 1.60 1.40
61
67
Ultimate Analysis
Carbon c % 70.14 67.90 75.70 73.32 76.30 69.20 76.20
Hydrogen H % 3.96 4.30 4.20 4.53 4.50 4.14 5.40
Oxygen O % 5.92 6.40 9.80 7.15 8.90 9.81 11.20
Nitrogen N % 1.40 1.40 1.70 1.57 0.80 1.15 1.50
Sulphur (combustible) S % 1.09 0.50 0.30 0.61 0.60 0.96 0.40
Ash A % 17.49 9.50 8.30 12.82 8.90 14.74 5.30
Total 100 100 100 100 100 100 100
Grindability HGI 54.00 58.00 70.00 50.00 56.00 50.00 48.00
Ash Composition (dry basis)
Silica Dioxide SiO2 % 47.00 65.90 61.00 74.00 52.80 44.10 51.00
Aluminum Xxxxxxxx Xx0X0 % 35.00 26.10 31.20 17.80 18.93 27.11 31.00
Iron Trioxide Fe2O3 % 5.40 2.00 2.95 4.40 17.45 9.72 10.00
Calcium Oxide CaO % 4.57 0.46 0.75 0.80 3.05 13.84 1.30
Titanium Dioxide TiO2 % 1.69 1.15 1.66 0.80 0.80 0.94 1.00
Magnesium Oxide MgO % 0.81 0.33 0.46 0.20 1.51 0.72 1.20
Sulphur Trioxide SO3 % 2.83 0.10 0.32 1.30 2.27 3.90 0.50
Phosphate Pentaoxide P2O5 % 1.38 0.14 0.31 0.01 0.24 0.50
Sodium Trioxide Na2O % 0.49 0.09 0.41 0.10 0.39 0.34 1.50
Potassium Oxide K2O % 0.61 2.01 0.36 0.40 1.24 0.21 1.80
Ash Fusion Temperatures
Initial Deformation IDT oC 1,370 1,340 1,410 -- 1,260 -- --
62
68
Softening ST oC 1,580 1,450 1,450 1,400 1,280 1,321 --
Hemispherical HT oC 1,600 1,450 1,450 1,560 1,320 1,538 1,350
Fluid FT oC 1,600 -- 1,450 1,560 1,390 1,538 --
Note: 1) Type "A" Coal is the Performance Coal for the purposes of this
Agreement.
2) CEPA and NPC shall meet within six (6) calendar months after
Financial Closing to agree allowable ranges of coal properties
generally based on the above table provided that if agreement
cannot be reached then the above table shall apply.
63
69
II. LIGHT OIL SPECIFICATIONS:
Gross caloric value, Kcal/kg 10,000
Specific Gravity, API at 15.56 (degree) C 0.82 to 0.86
Viscosity, SSU at 37.78 (degree) C 33.5
Pour Point, (degree) C -6.7
Flash Point, (degree) C 66
Water Content, (max) % by wt. Trace
Sulphur Content, (max) % by wt. 1.0
Ash Content, (max) % by wt. 0.01
III. HEAVY OIL SPECIFICATIONS:
Gross caloric value, Kcal/kg 10,000
Gravity, API at 15.50 (degree) C 0.95
Flash Point, (degree) C 82.22
Pour Point, (degree) C 4.44
Viscosity, SSU at 37.78 (degree) C 2,500
Sulphur, % by wt. 3.5
Water and sediment, % by wt. 0.10
Ash, % by wt. less than 0.10
Vanadium, ppm 200 maximum
Sodium, ppm 100 maximum
64
70
FIFTH SCHEDULE
Transmission Line Specifications
LOCATION
From the outgoing sides of the high voltage switchyard within the Site to the
relevant and specific termination and interconnection point on the Luzon grid as
determined by NPC.
SPECIFICATION
The Transmission Line shall be designed and constructed in accordance with
internationally accepted standards.
The Transmission Line shall be capable of providing sufficient electricity for
testing, commissioning and starting the Power Station and shall be capable of
taking the maximum output of the Power Station, and shall be completed within
the agreed construction program for the Power Station as stipulated in Article
13.
The Transmission Line shall be complete in all aspects and composed of but not
limited to: structural steel towers capable of withstanding all stresses induced
and/or caused by environmental, electrical and mechanical stresses, aluminum
wire and cables, dampers, insulators, attachment hardwares, other appurtenances
and hardwares, protective xxxxxxx and earthing systems.
The scope of supply of the Site terminal attachment shall be as shown in the
attached "230KV Transmission Line Site Terminal Attachment Scope of Supply".
65
71
[GRAPHIC]
SUAL THERMAL POWER PROJECT
230KV TRANSMISSION LINE
SITE TERMINAL ATTACHMENT
SCOPE OF SUPPLY
65-A
72
SIXTH SCHEDULE
ELECTRICITY DELIVERY PROCEDURES
DEFINITION
1. "PLANNED OUTAGE" means the number of days per Unit per year allowed to
CEPA by NPC to undertake annual test (if outage is required) and the
scheduled normal inspection, maintenance, repair and overhaul. Outage
shall be counted from the time the Unit is disconnected from the grid up
to the time it is connected to the grid.
"UNPLANNED OUTAGE" means the number of days per Unit per year that CEPA
is unable to operate when requested by NPC. Dispatch order of NPC,
faults in or failure of the Transmission Line, and Force Majeure
events as provided in paragraph (b) of Article 14.1 shall not be
considered as unplanned outage.
2. ALLOWED OUTPUT
Specific procedures for notification of power requirements shall be
agreed between CEPA and NPC prior to a Unit Completion Date in respect
of Unit 1. Subject to such procedures, the outputs of the Units shall be
as required by the system controller from time to time, provided that
changes in output requested by the system controller remain within the
Specifications and the Operating Parameters.
3. NOTICE OF PLANNED OUTAGE
NPC shall prepare annual, monthly and weekly Availability Schedules and
in so doing shall coordinate with CEPA to agree on Planned Outage. NPC
shall grant CEPA allowable Planned Outage to undertake all regular
inspection and maintenance in accordance with the manufacturer's
recommendations.
CEPA will be allowed a total of thirty (30) days per Unit per year for
Planned Outage. CEPA will plan with NPC to ensure that as far as
practicable, Planned Outage is undertaken at times to cause mininium
disruption to the NPC power supply.
In case of Unplanned Outage, CEPA shall immediately inform NPC of the
nature and estimated duration of Unplanned Outage. CEPA is allowed
twenty-five (25) days per Unit per year for Unplanned Outage. Subject
to Article 4.8, the number of days of Unplanned Outage allowed CEPA in
any year shall be increased by the number of days during which any Unit
is not operating by reason of calibration or other work (but not repair
work) undertaken in relation to an optional test required by NPC
pursuant to such Article.
If CEPA exceeds the Planned Outage for one year, it shall be allowed to
utilize its allowed Unplanned Outage. Conversely, if the Planned Outage
is not utilized, it shall be credited to the allowed Unplanned Outage.
Furthermore, if in any year of the total available period of outages is
not utilized, the excess shall be carried forward and added to the
allowance for the next year.
4. NOTICE OF REQUIRED ELECTRICITY
While the annual, monthly and weekly Availability Schedules will be
prepared by NPC considering the guaranteed Net Contracted Capacity and
the Planned Outage schedule, it is agreed that the weekly plan for the
following seven days will be the control plan and will be that plan
referred to as a "normal operation plan".
66
73
5. Normal Operations
Normal operations of the Units are as defined below:
(a) operating in accordance with the weekly normal operation plan
as defined in Section 4 above as agreed in writing between
NPC and CEPA.
(b) Operating with Fuel within the specifications set out in the
Fourth Schedule (Specifications for Fuel Supply).
(c) Subject to the provisions of Article 3.15, operating at Net
Contracted Capacity with a cooling water temperature rise not
exceeding 7 deg. C.
(d) Operating frequencies of the system to be within the limits
of the Operating Parameters.
(e) Operating at a system voltage of 230 KV plus or minus 5%.
(f) Start-up, synchronizing and loading to be within the limits
of the Operating Parameters.
(g) Full access to the Site at all times for materials and
personnel.
67
74
SEVENTH SCHEDULE
MEASUREMENT AND RECORDING OF ELECTRICITY
1. METER OWNERSHIP AND MAINTENANCE
CEPA shall own and maintain meters and related equipment meeting
specifications mutually agreed between NPC and CEPA to be utilized for
the measurement of electric power and energy in determining NPC's
payments to CEPA pursuant to this Agreement.
2. MEASUREMENT OF POWER GENERATED AND METER LOCATION
Measurement of power generated and delivered to NPC shall be made at
the high-voltage side of the main power transformer of each Unit. The
equipment used for metering the power and energy delivered to NPC shall
be located as indicated in Exhibit II.
3. METER READING AND VERIFICATION
In order to verify the quantity of electricity delivered by CEPA to NPC
in each Month, NPC and CEPA shall at noon or at such other time agreed
between NPC and CEPA on the twenty fifth day of each calendar month
take a photograph of the electricity meters (M(1) and M(2) in Exhibit
II) in the Power Station recording the supply of electricity by CEPA
Provided always that if either party shall not be present at the
relevant meter or meters at the agreed time, the above-mentioned
photograph shall be taken by the party present and shall be binding on
the party absent.
4. METER TESTS
CEPA's meters, installed in pursuance to this Agreement, shall be tested
by NPC in the presence of CEPA at CEPA's expense every six (6) calendar
months. Other tests may be conducted at any reasonable time upon request
by either party, at the requesting party's expense. If NPC makes such
request, NPC shall reimburse said expense to CEPA within thirty (30)
days after presentation of a xxxx therefor. CEPA's meter test results
shall be deemed final and conclusive.
5. METER ACCURACY
Metering equipment found to be inaccurate shall be repaired, adjusted,
or replaced by CEPA such that the accuracy of said equipment shall be
within 100% plus or minus two per cent (2%). Should the inaccuracy
exceed plus or minus two per cent (2%), the correct amount of power
energy delivered during the previous billing period shall be estimated
by CEPA and agreed by the parties. Adjustment for meter inaccuracy shall
cover only the current billing period and the billing period
immediately preceding it except when such meter inaccuracy is due to
fraud.
6. METER SEALS AND INSPECTION
CEPA's meters shall be sealed and the seals shall be broken only when
the meters are to be read, inspected or tested pursuant to Sections 3, 4
and 5 above. CEPA shall be given reasonable notice of such occasions and
shall have the right to have its representative present.
7. IMPORTED POWER
NPC and CEPA shall agree on the procedures for the measurement of
electricity delivered by NPC to the Power Station.
68
75
EIGHTH SCHEDULE
Delivery of Power and Energy
1. OBLIGATIONS OF PARTIES. CEPA hereby agrees to convert Fuel supplied by
NPC into electricity and NPC hereby agrees to take at the high voltage
side of the step-up transformer, the electric power and energy delivered
by CEPA to NPC until the Transfer Date.
2. CAPACITY PROVISION. CEPA shall deliver and NPC shall receive and pay for
the Nominated Capacity of the Units as provided in Section 4 of this
Schedule.
Each Unit will be tested on or before its Unit Completion Date and, if
required by NPC, on each anniversary thereof, to prove Nominated
Capacity at guarantee tests conducted in accordance with Section 4 of
the Thirteenth Schedule (Test and Inspection). If the net kilowatt
capability proven at any such test is lower than that nominated by CEPA,
Nominated Capacity shall mean the proven net kilowatt capability for the
period commencing on the date of such test until such later date as
CEPA is able to prove a higher net kilowatt capability.
3. DELIVERED ENERGY. CEPA shall convert Fuel supplied by NPC into
electricity and deliver it to NPC, and NPC shall take such electricity
from CEPA as requested by the NPC Power Management Centre. The energy
delivered shall be paid for by NPC pursuant to the terms and
conditions as provided in Section 4.1.2 of this Schedule.
Each Unit will be tested on or before its Unit Completion Date and, if
required by NPC, on each anniversary thereof, to prove its Unit Net Heat
Rate at guarantee tests conducted in accordance with Section 4 of the
Thirteenth Schedule (Test and Inspection). If the Unit Net Heat Rate
proven at any such test is greater than the guaranteed Unit Net Heat
Rate for the year, then CEPA shall endeavour to undertake corrective
measures on the Unit to achieve the guaranteed Unit Net Heat Rate. In
such event, the application of Section 4.1.2 hereof shall be based on
the proven Unit Net Heat Rate for the period commencing on the date of
such test until such later date as CEPA is able to prove a lower Unit
Net Heat Rate.
4. TERMS OF PAYMENT
4.1 BASIC POWER PLANT
4.1.1 The Capacity Fees shall be the sum of the capital costs,
fixed operating costs, and return on investments on the
basic Power Plant. Capacity Fees shall be computed on
the basis of the following formulae:
(a) Capital Cost Recovery Fee (A)
A = [(CCR(P) X E(A)) - (Y X 1.05) X (CCR(P)
(E(C) - E(N))]
(b) Fixed Operating Cost Fee (B)
B = [(OCR(P) X E(A)) - (Y X 1.05) x (OCR(P))
(E(C) - E(N)]
(c) Service Fee to Reflect Return of Investments (C)
C = [(SFR(P) x E(A)) - (Y x 1.05) x (SFR(P))
(E(C) - E(N))]
where,
A = Capacity payment to recover capital cost for
the billing period.
69
76
B = Capacity payment to recover fixed operating cost for the
billing period.
C = Capacity payment to reflect return on investment of
Operator for the billing period.
CCR(P) = Contract Capacity Rate for capital costs of the basic
Power Plant
= $0.0230/KWHR for Period 1
= $0.0201/KWHR for Period 2
= $0.0172/KWHR for Period 3
OCR(P) = Contract Capacity Rate for basic Power Plant's fixed
operating costs per kilowatthour
= $0.0014/KWHR and ps 0.00833/KWHR for Period 1
= $0.0012/KWHR and ps 0.00833/KWHR for Period 2
= $0.0010/KWHR and ps 0.00833/KWHR for Period 3
SFR(P) = Service Fee Rate for basic Power Plant's return on
investment
= per kilowatthour
= $0.0023/KWHR for Period 1
= $0.0020/KWHR for Period 2
= $0.0017/KWHR for Period 3
CC = Net Contracted Capacity, in KW
NC = Nominated Capacity for the Year, in KW
E(C) = Contracted Energy for the billing period
= CC x (A(O) - P(O) - U(O))
E(N) = Nominated Energy for the billing period, KWHR
= NC x (A(O) - P(O) - U(O))
E(A) = Adjusted energy generation, KWHR
= E(M) + E(D) + E(O) + E(Q)
If E(A) > E(N) + E(O), the value of E(N) + E(O) shall be
used in place of E(A)
E(M) = Measured energy in the HV side of the transformer, KWHR
E(D) = Undelivered energy due to NPC's dispatch order based on
the difference of Nominated Capacity (NC) and dispatch
order of NPC(D)
= (NC - D) x T(D)
E(O) = Energy credit due to allowable Planned and Unplanned
Outage based on Nominated Capacity, KWHR
= NC x (U(O) + P(O))
E(Q) = Energy not delivered for reasons not attributable to fault
of CEPA, its agents, authorized representatives or
contractors
70
77
(including without limitation NPC's inability to
provide Fuel and failure of Transmission Line but
excluding undelivered energy already covered by E(D) and
E(O)), KWHR
= NC x T(F)
A(O) = Total hours in the billing period, hrs
P(O) = Allowable Planned Outage in the billing period, hrs
U(O) = Allowable Unplanned Outage in the billing period, hrs
D = Reduced load as requested by NPC, KW
T(D) = No. of hours the dispatch order of NPC is in affect
T(F) = No. of hours that the Unit is unable to deliver energy
for reasons not attributable to fault of CEPA
Y = Variable
= If NC > 0.95 x CC, Y = O
-
= If NC < 0.95 x CC, Y = 1
For purposes of this Section 4.1.1 and for Sections 4.1.2 and 4.2 below, in
respect of each Unit, "PERIOD 1" shall mean the period commencing on the date
when the relevant fee becomes first payable up to and including the last day of
the tenth year of the Cooperation Period for such Unit; "PERIOD 2" shall mean
the period commencing upon the expiry of Period 1 and ending on the last day of
the twentieth year of the Cooperation Period of such Unit; and "PERIOD 3" shall
mean the period commencing upon the expiry of Period 2 and ending on Transfer
Date.
4.1.2 Energy Fees shall be computed on the basis of the following formula:
D=(E(m) x BER) + (UxE(m) x (HR)(g) - HR(t))
-------
1000xHHV
D = Energy Fees in dollars and pesos for the billing period
E(m) = KWHR delivered as measured in the meter at the HV side
of the transformer
BER = Base Energy Rate, in dollars and pesos, per KWHR
delivered
= $0.0017/KWHR and ps0.00833/KWHR for Period 1
= $0.0015/KWHR and ps0.00833/KWHR for Period 2
= $0.0012/KWHR and ps0.00833/KWHR for Period 3
U = Weighted average of coal price (CIF) in dollars per
metric tonne based on the average of last three (3)
purchases made by NPC prior to the billing period
HHV = Weighted average of the Coal Higher Heating Value (CIF)
in "as received" basis of the of last three (3)
purchases made by NPC prior to the billing period,
Kcal/kg
71
78
HR(g) = Guaranteed Unit Net Heat Rate for the year as set forth
in Section 6 of the Second Schedule, Kcal/KWHR
HR(t) = Tested Unit Net Heat Rate at Net Contracted Capacity
taken at the commissioning date and after every year
thereafter, Kcal/KWHR
4.2 Infrastructure Fees (E) shall reflect the recovery of the capital
costs and debt service for Infrastructure and common facilities
E = [(BIF X E(A)) - (Y x 1.05) X BIF (E(C) - E(N))]
where, E = Capacity Fee to recover infrastructure cost for the
billing period
BIF = Basic Infrastructure Fee per KWHR
= $0.00137/KWHR for Period 1
= $0.00120/KWHR for Period 2
= $0.00103/KWHR for Period 3
4.3 Fees Adjustment Provision
On Unit Completion Date for Unit 1 and every six (6) calendar months
thereafter, the amount of (i) the Energy Fee and (ii) the Fixed
Operating Fee shall be increased or decreased proportionately to the
average of any increase or decrease of:
(a) (i) the Japanese Export Price Index (excluding Agricultural
Products) taken from the International Financial
Statistics published by the International Monetary
Fund (the "JAPANESE INDEX");
(ii) the U.S. Export Price Index (excluding Agricultural
Products) taken from the International Financial
Statistics published by the International Monetary
Fund (the "U.S. INDEX"); and
(iii) the Export Price Index of all European country to be
agreed between the parties hereto (excluding
Agricultural Products) taken from the International
Financial Statistics published by the International
Monetary Fund (the "EUROPEAN INDEX"); or
(b) the National Economic and Development Authority's retail
price index for all items in Metropolitan Manila (the
"PHILIPPINES INDEX"),
from the levels of such indices prevailing on 14 January 1994.
If any of the indices referred to in Section 4.3 above ceases to exist
or to be published, the relevant increase or decrease shall be the
increase or decrease in the index replacing or revising such index or
such other index agreed by the parties. Accordingly, on any given
adjustment date, the Energy Fees and the Fixed Operating Fee, shall be
each escalated by a factor as follows:
72
79
JIC + USIC + EIC
--- ---- ---
Dollar Denominated Fees: AF = JIB USIB EIB
----------------------
3
Peso denominated fees: AF = PIC
---
PIB
Where:
AF = the Adjustment Factor
JIB = the Japanese Index as at 1 January 1994 or a date
nearest thereto in the same year
FIC = the Japanese Index six month immediately preceding the
adjustment date
USIB = the U.S. Index as at 1 January 1994 or a date nearest
thereto in the same year
USIC = the U.S. Index six month immediately preceding the
adjustment date
EIB = the European Index as at 1 January 1994 or a date
nearest thereto in the same year
EIC = the European Index six month immediately preceding the
adjustment date
PIB = the Philippines Index as at 1 January 1994 or a date
nearest thereto in the same year
PIC = the Philippines Index six month immediately preceding
the adjustment date
4.4 For clarity in the interpretation and application of the above
formulae, sample computations of the Capacity and Energy Fees as well
as the penalty for delayed completion are shown in the Fifteenth
Schedule (Sample Computations of Monthly xxxxxxxx, Start-up Charges,
Penalties and Incentives).
73
80
NINTH SCHEDULE
Insurance
1. INSURANCE DURING CONSTRUCTION. During the period from the date hereof
up to the Unit Completion Date of Unit 2, whenever and to the extent
necessary, CEPA shall, on a timely basis and at its own expense, obtain
and maintain in force the following insurances:
(a) A Marine insurance in respect of plant equipment to be
imported into the Philippines;
(b) All Risks "Builder's Risk Insurance" to cover the entire works
from any and all kinds of damages arising out of any cause
whatsoever;
(c) "Third Party Liability Insurance" to cover injury to or death
of persons (including those of NPC) or damage to property
caused by the works or by CEPA's vehicles, tools and/or
equipment or personnel including its sub-contractors; and
(d) "Workmen's Compensation Insurance" as required under the
Social Security Law.
2. INSURANCE DURING COOPERATION PERIOD. During the period commencing on
the Unit Completion Date in respect of Unit 1 and ending on the
Transfer Date, CEPA shall at its own expense keep the Power Station
insured against accidental damage from all normal risks and to a level
normal for prudent operators of facilities similar to the Power
Station. In addition, CEPA shall secure adequate insurance cover for
its employees as may be required by law.
3. The insurance effected shall be no less favourable to the insured in
terms of risks covered than that normally effected by NPC in respect of
its own similar operations.
4. CEPA shall provide NPC with copies of all policies of insurance
effected by it.
74
81
TENTH SCHEDULE
FORM OF PERFORMANCE UNDERTAKING
To: CEPA Pangasinan Electric Limited ("CEPA") and
Pangasinan Electric Corporation ("CEPA PHILLIPINES" and,
together with CEPA, the "BENEFICIARIES" which expression
includes each Beneficiary)
[Date]
Dear Sirs,
We refer to the arrangements for CEPA to make an investment in a power station
to be built in the Philippines recorded in an energy conversion agreement dated
[ ] made between National Power Corporation ("NPC") (which is
wholly-owned by us) and CEPA and an accession undertaking dated [ ], whereby
CEPA PHILIPPINES was joined as a party to the energy conversion agreement (the
energy conversion agreement, as supplemented by the accession undertaking and as
further supplemented and amended from time to time, the "AGREEMENT"). We are
fully aware of the terms and conditions of the Agreement.
In order to facilitate these investment arrangements we hereby confirm that the
obligations of NPC under the Agreement carry the full faith and credit of the
Republic of the Philippines, and that the Republic of the Philippines will see
to it that NPC will be able to discharge, at all times, such obligations as they
fall due. Such obligations are hereby affirmed and guaranteed by the Republic of
the Philippines.
Any dispute, controversy or claim arising out of or relating to this
undertaking, or the breach or termination thereof or the failure to pay or the
late payment of any sum due shall be settled by Arbitration in Sydney, Australia
in accordance with the UNCITRAL Arbitration Rules in force at the date of this
undertaking. The appointing authority shall be The Australian Commercial
Disputes Centre, Sydney, the number of arbitrators shall be three and the
language to be used in the arbitral proceedings shall be English. The parties
exclude any right of application or appeal to any courts in connection with any
question of law arising in the course of arbitration or with respect to any
award made.
We waive for ourselves and our assets and revenues to the extent permitted by
applicable law any and all immunity from suit, execution or other legal process;
notwithstanding the foregoing, we do not waive any such immunity in respect of
property which is (i) used by a diplomatic or consular mission of the
Philippines, (ii) property of a military character and under the control of a
military authority or defence agency and (iii) located in the Philippines and
dedicated to a public or governmental use.
Yours faithfully,
THE REPUBLIC OF THE PHILIPPINES
By:
Secretary of Finance
75
82
ELEVENTH SCHEDULE
FORM OF ACCESSION UNDERTAKING
THIS ACCESSION UNDERTAKING is made the [ ] day of [ ] 1994
BY
CEPA PANGASINAN ELECTRIC LIMITED, a private corporation, duly organized and
existing under the laws of the British Virgin Islands with registered office at
X.X. Xxx 00, Xxxxxxxxx Xxxxxxxx, Xxxx Town, Tortola, British Virgin islands,
represented by its directors, Xxxxxx Xx Xxxx Xxxxxx and Xxxxxxx X.X. Xxxxxx who
are duly authorized to represent it in this Agreement, hereinafter referred to
as CEPA
NATIONAL POWER CORPORATION, a government owned and controlled corporation duly
organized and existing under the law and by virtue of Republic Act No. 6395, as
amended, with its principal office at the corner of Xxxxx Xxxx xxx Xxxxxx
Xxxxxx, Xxxxxxx, Xxxxxx Xxxx, Xxxxxxxxxxx, represented herein by its President,
Xxxxxxxxx X. Xxxxx, who is duly authorized to represent it in this Agreement,
hereinafter referred to as NPC
PANGASINAN ELECTRIC CORPORATION, a corporation incorporated in the Republic of
the Philippines and having its registered office at [ ], Philippines represented
by its President, Xxxxxxx X. Xxxxxxxx, who are duly authorized to represent it
in this Agreement, hereinafter referred to as CEPA PHILIPPINES
WHEREAS
(A) This Undertaking is supplemental to an energy conversion agreement (the
"PROJECT AGREEMENT") dated [ ], 1994 and made between (1) NPC and (2)
CEPA whereby CEPA has agreed to design, built and operate a coal fired
thermal power station in the Philippines and transfer the same to NPC
on the Transfer Date (as defined therein).
(B) CEPA PHILIPPINES is a Philippine corporation and a subsidiary of CEPA.
(C) It is a condition precedent to the effectiveness of the Project
Agreement that the parties hereto enter into this Accession
Undertaking.
NOW IT IS HEREBY AGREED as follows:
ARTICLE I
INTERPRETATION
(A) Terms defined in the Project Agreement shall bear the same meaning
herein.
(B) This Undertaking shall take effect on the date hereof.
(C) Article headings are for ease of reference only.
(D) In this Undertaking, the singular includes the plural and vice versa.
76
83
ARTICLE 2
ACCESSION OF CEPA PHILIPPINES
(A) CEPA PHILIPPINES shall become a party to the Project Agreement and
shall perform and comply with all the obligations on the part of CEPA
under the Project Agreement which necessarily have to performed in
the Philippines in respect of the development, construction and
operation of the Project, including the importation into the
Philippines of all equipment for the Project and the operation of the
Power Station and all reference to "CEPA" in the Project Agreement
(including without limitation in Articles 2, 3, 4, 5, 7, 8, 9 and 27
thereof) shall be construed to be reference to CEPA PHILIPPINES to the
full extent necessary to give effect to the foregoing.
(B) NPC shall perform all obligations on its part under the Project
Agreement as if CEPA PHILIPPINES were named in the Project Agreement as
a party thereto and CEPA PHILIPPINES shall be entitled to all the
rights, benefits and interests under the Project Agreement as if it
were named as a party thereto including (without limitations) the
benefits of all warranties and undertakings on the part of NPC in the
Project Agreement.
(C) CEPA shall be jointly and severally liable with CEPA PHILIPPINES for
the performance of the obligations undertaken by CEPA PHILIPPINES under
Article 2(A) above, and undertakes to NPC that it shall, promptly upon
its receipt of written demand from NPC, perform such obligations in
accordance with the provisions of the Project Agreement.
(D) Subject only to the above provisions, the Project Agreement and the
respective rights and obligations of the Parties thereto under it
shall continue in full force and effect.
ARTICLE 3
REFERENCE IN THE PROJECT AGREEMENT
As from the date hereof, any reference in the Project Agreement to "THIS
AGREEMENT" and any reference, whether express or implied, to a clause or
provisions of the Project Agreement shall be deemed to be a reference to the
Project Agreement and to an article or provision thereof as hereby supplemented
and amended.
ARTICLE 4
ASSIGNMENT
CEPA PHILIPPINES and CEPA may for the purpose of arranging or rearranging
finance for the Project, assign or transfer all or any part of its rights and
benefits of the Project Agreement as hereby supplemented and NPC shall duly
acknowledge any such assignment or transfer of which it is given notice.
ARTICLE 5
LAW AND JURISDICTION
The provisions of Article 20, 22 and 24 of the Project Agreement shall apply to
this Undertaking as if the same were herein repeated in full mutatis mutandis.
77
84
CEPA PANGASINAN ELECTRIC LIMITED
By:
in the presence of:
NATIONAL POWER CORPORATION
By:
in the presence of:
PANGASINAN ELECTRIC CORPORATION
By:
in the presence of:
78
85
TWELFTH SCHEDULE
FORM OF LEGAL OPINION OF NPC'S GENERAL COUNSEL
From: General Counsel of NPC
To: CEPA Pangasinan Electric Limited and Pangasinan Electric Corporation
[Date]
Dear Sirs,
I have acted on behalf of National Power Corporation (NPC) in connection with an
Agreement ("the PROJECT AGREEMENT") dated [ ] and made between NPC (1) and
CEPA Pangasinan Electric Limited (CEPA) (2) and, an agreement ("the ACCESSION
UNDERTAKING" together with the Project Agreement, the "AGREEMENTS) dated [ ],
19[ ] and made between CEPA (1) NPC (2) and Pangasinan Electric Corporation
(3). I have examined executed copies of the Agreements and such other documents
as I have considered necessary or desirable to examine in order that I may give
this opinion. Terms defined in the Agreements shall have the same meaning
herein.
I am of the opinion that:
(i) NPC is a public corporation and validly existing under the laws of the
Republic of the Philippines pursuant to Republic Act No. 6395 (as
amended);
(ii) NPC has the corporate or other power to enter into the Agreements and
to exercise its rights and performs its obligations thereunder, and
executions of the Agreements on behalf of NPC by the person(s) who
executed the Agreements was duly authorized by NPC;
(iii) all acts, conditions and the things requires by the laws and
constitution of the Republic of the Philippines to be done, fulfilled
and performed in order (a) to enable NPC lawfully to enter into,
exercise its rights under and perform the obligations expressed to be
assumed by it in the Agreements, (b) to ensure that the obligations
expressed to be assumed by it in the Agreements are valid and
enforceable by appropriate proceedings and (c) to make the Agreements
admissible in evidence in the Republic of the Philippines have been
done, fulfilled and performed in compliance with the laws and
constitution of the Republic of the Philippines;
(iv) the obligations expressed to be assumed by NPC in the Agreements are
legal and valid obligations binding on NPC enforceable in accordance
with the terms thereof;
(v) NPC is not entitled to claim any immunity from suit, execution,
attachment or other legal process in the Republic of the Philippines;
and
(vi) under the Constitution of the Philippines, it is recognized that no law
impairing the obligations of contracts shall be passed and consequently
the validity of the Agreements and the binding nature of the
obligations of the party thereunder are constitutionally safeguarded.
This opinion is confined to matters of Philippine law and no opinion is
expressed as to the laws of any other jurisdiction.
Yours faithfully,
79
86
THIRTEENTH SCHEDULE
TEST AND INSPECTION
INTRODUCTION
Test are to be undertaken by CEPA to ensure that the Power Station will perform
in accordance with agreed specifications and parameters.
METHODOLOGY
Unless otherwise provided, the test methods employed and the test result
calculations shall be in accordance with the latest American Society of
Mechanical Engineers (ASME), Power Test Code, Institute of Electrical and
Electronics Engineering (IEEE), Energy Power Research Institute (EPRI) or
equivalent internationally-accepted standards.
The tests shall be conducted using all panel instruments installed in the
control room unless otherwise required to use additional instrumentation. All
instruments shall be calibrated prior to testing.
Detailed test procedures shall be agreed by NPC and CEPA not later than three
(3) months before the date of the actual test.
TEST
The following are the tests to be conducted by CEPA:
1. PRELIMINARY TEST AT SITE
Preliminary tests shall be carried out at Site to ascertain correct
execution of the erection works and tuning of the installed equipment
and to verify characteristics and performance of equipment.
Preliminary tests at site shall include the following:
(a) Radiographic Examination
(1) 100% of main steam and reheat steam line welding.
(2) 30% of water wall tubes, economizer, superheater,
reheater and other pressure parts. Should welding
failure occur, the percentage shall be subsequently
doubled.
(b) Hydrostatic test of pressure parts at 1.5 times the design
pressure as required.
(c) Leak test on condenser and generator H2 cooling system.
(d) Pressure tests on ducts.
(e) Functional test of all equipment and plant system.
(f) Safety valve setting.
(g) Automatic intervention of standby equipment, where possible.
(h) Balancing and vibration test of rotating equipment, where
useful.
80
87
(i) Checking of all safety devices.
(j) Other tests necessary to ascertain the safety and reliability
of the Facility.
All the above tests shall meet all the requirement of the
specifications before any Performance and Efficiency Tests shall be
performed.
2. PERFORMANCE TEST
Performance Test on the Power Station shall ascertain the safety and
reliability of the Power Station and its associated equipment in
accordance with the contract provisions and guarantees. Performance
Tests shall be performed prior to Efficiency Tests.
The Performance Tests shall include the following:
(a) STEAM GENERATOR AND AUXILIARIES (WITHOUT ANY MANUAL ADJUSTMENT
DURING THE TEST)
(1) Attainment of guaranteed output using pulverized
coal.
(2) Guaranteed start-up time from cold start to full
load, and hot start to full load.
(3) Keeping of the main steam pressure at rated value
from 50% to MCR of Rated Capacity.
(4) Keeping of rated value of main steam temperature from
60% to MCR of Rated Capacity.
(5) Tripping of the plant at loads of 50%, 75%, 100% and
MCR of Rated Capacity shall be tested. No perjuring
malfunction or endangering of the equipment shall
take place and all controls shall operate safely.
(6) Rapid reduction of load when the load is above 50% of
rate output, due to failure of either forced draft
fan or induced draft fan, or failure of circulating
water pump or of boiler feedwater pump without
intervention of the standby pump, or turbine load
reduction due to turbine auxiliary failure.
(7) Verification of silica content of main steam and
steam from the drum at all loads.
(8) Excess air at various loads.
(9) Air leakage in the air heaters.
(10) Guaranteed performance of steam coil air heaters.
(11) Guaranteed flue gas temperature at furnace exit and
air heaters outlet.
(12) Automatic change-over of standby equipment (if any)
at all load.
(13) Verification of dust emission and SO(2) ground
concentration level.
(14) Correct operation of soot blowing system.
(15) Operating at minimum load firing pure coal.
(B) STEAM TURBINE AND AUXILIARIES (WITHOUT ANY MANUAL ADJUSTMENT
DURING THE TEST)
81
88
(1) Correct deaerating effect of condenser and deaerator.
(2) Verification of the guaranteed output.
(3) Performance and correct operation of all equipment.
(4) Tripping.
(5) Capability to sustain rapid reduction of load arising
from failure of turbine auxiliaries.
(6) Automatic change-over of standby equipment, if any.
(7) Capability to sustain rapid reduction of load arising
from failure of boiler and its auxiliaries.
(c) COAL HANDLING PLANT
(1) Verification of the guaranteed capacity of coal
unloader, conveyors, stacker/reclaimer and crusher.
(2) Verification of power requirement of coal unloader,
conveyor, stacker/reclaimer and crusher.
(d) ASH HANDLING PLANT
(1) Verification of the guaranteed capacity.
(2) Verification of automatic change-over of standby
equipment.
(3) Verification of power requirements of blowers, pumps,
etc.
(e) WATER TREATMENT PLANT
(1) Verification of demineralized water quality.
(2) Verification of plant capacity.
(3) Verification of active life filters.
(4) Verification of automatic change-over of standby
equipment.
(5) Verification of automatic operation of the plant.
(f) AUXILIARY EQUIPMENT
(1) Load test of overhead crane.
(2) Load test of other cranes and hoisting equipment.
(3) Operation of firefighting equipment.
(4) Load test of air conditioning system.
(5) Performance of sodium hypochlorinator equipment.
(g) METEOROLOGICAL AND ENVIRONMENTAL EQUIPMENT
82
89
3. EFFICIENCY TEST
Efficiency test on each major equipment shall be conducted in order to
assure that the functioning of each part of the equipment is in
accordance with the contract provisions and guarantees.
The efficiency test to be conducted are as follows:
(a) STEAM GENERATOR
The efficiency test shall be carried out in accordance with
the provisions of ASME Power Test Code 4.1 - Heat Loss Method.
All conditions stipulated in the ASME PTC 4.1 shall be
followed as much as possible but certain provisions can be
waived if the conditions of the Code cannot be meet.
The efficiency test shall be conducted at 50% 75% and 100% of
Rated Capacity.
(b) TURBINE GENERATOR
The efficiency test shall be carried out in accordance with
the provisions of ASME PTC 6.1.
Efficiency test shall be conducted at 50% 75% and 100% of
Rated Capacity.
(c) AUXILIARY POWER CONSUMPTION
All auxiliary power consumption at 100% load shall be
measured. The total auxiliary power consumption of the Power
Station shall be measured simultaneously and include but not
limited to turbine auxiliaries, boiler auxiliaries, controls,
water treatment, coal handling, domestic water supply and
other consumers. The power consumption of coal handling, water
treatment and other intermittent auxiliaries shall be
pro-rated to the tested load measured in item (b).
4. GUARANTEE TESTS
For the purpose of verifying the Nominated Capacity and Unit Net Heat
Rate of each Unit for the calculation of fees to be paid to CEPA by
NPC, guarantee tests shall be carried out by CEPA on Unit Completion
Date and, if required by NPC, every anniversary date thereafter. CEPA
shall give NPC reasonable notice of such tests and NPC shall have the
right to be present during testing.
CEPA and NPC shall sign a joint certificate stating the results of each
guarantee test.
The parties will meet in good faith with the view to agreeing, not
later than three (3) months before the actual test prior to Unit
Completion Date for Unit 1, on simplified procedures consistent with
the requirements of accuracy and ease of application, under which all
tests under this Section will be conducted. The ASME Power Test Codes
will not be applied to such tests, however, the parties may agree on
any test procedure proposed by CEPA including a modified version of the
ASME Power Test Codes, and every effort will be made to minimize
disruption of operations and avoid shut-down of the Unit under test.
The first such test shall be conducted before Unit Completion Date for
Unit 1, simultaneously with the efficiency test referred to in Section
3 above, and the results compared so that the parties may mutually
agree on any revisions to procedures.
For purposes of the test to demonstrate that each Unit is capable of
producing Nominated Capacity, the measuring points shall be the
electricity supply meters referred to in the Seventh Schedule
(Measurement and Recording of Electricity) given that calibration of
the meters shall
83
90
be carried out by CEPA and NPC prior to testing of the Net Contracted
Capacity. For purposes of calculating Unit Net Heat Rate, the measuring
points of power delivered by CEPA to NPC shall also be the meters
referred to in the Seventh Schedule (Measurement and Recording of
Electricity). A test result for Unit Heat Rate that is within plus or
minus 1.0 percent of the applicable guaranteed Unit Net Heat Rate as
set out in Section 6 of the Second Schedule (Operating Parameters)
shall be deemed to indicate exact compliance with such guaranteed Unit
Net Heat Rate.
The tests for Nominated Capacity and Unit Net Heat Rate will be carried
out simultaneously for the Unit under test and will be conducted under
steady conditions using Performance Coal.
84
91
FOURTEENTH SCHEDULE
REQUIRED PROJECT DESCRIPTION DATA FOR ENVIRONMENTAL IMPACT ASSESSMENT STUDY
CEPA shall prepare the Environmental Impact Assessment Study and shall cover the
following:
1. Name and Address of CEPA/CEPA PHILIPPINES
2. Type of Project
3. Overview/Summary
4. Project Setting
(a) Declaration and Objectives
(b) The Need for Project (Power)
(c) Associated Projects
5. The Proposal
(a) General Layout and Location
Exact project location properly superimposed on a 1:50,000
scale topographic map and detailed site layout of project
facilities.
(b) Size and scale of project in terms of electricity output and
fuel/other inputs, its projected life span and project cost.
(c) Pre-Construction Details
(d) Construction Details
Detailed work program (i.e. from construction and
implementation stage), including the number of workers in each
phase of project development.
(e) Operation and Maintenance
(1) Plan of operation, process flow description and flow
chart
(2) All outputs of project, including gaseous and
particulate emissions, liquid effluents, and
atmospheric emissions should be described in terms of
components and rate of production and discharge.
(3) Description of waste disposal or management system,
including detailed description of facilities and
measures to be adopted to minimize adverse
environmental effects.
(f) Contingency Plans
(1) Spontaneous Combustion
(2) Fire
(3) Oil Spill
85
92
(4) Coal Spill
(g) Abandonment
(h) Air Pollutant Dispersion Modelling Data
(1) Plant Capacity and Capacity Factor
(2) Plant Efficiency
(3) Stack Diameter
(4) Stack Height
(5) Stack Gas Exit Temperature and Velocity
(6) Fuel Consumption, tons/hr
(7) Coal HHV, kcal/kg
(8) Coal Sulfur and ash content, trace metals
(9) SO(2) emission concentration, sulfur in bottom ash
(10) NO(x) emission concentration
(11) Ambient temperature
(i) Wastewater Quality and Water Use
(1) temperature rise in cooling water system, CWS flow
rate
(2) fresher use rate (provide breakdown)
(3) wastewater volumes and characteristics
86
93
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
NOTE: ALL CALCULATIONS ARE ON A PER UNIT BASIS
1. PENALTY FOR LATE COMPLETION
Target Unit Completion Date July 31 1997
Actual Completion Date December 1 1997
Delay In Completion 123 Days
Grace Period 30 Days
Net delay subject to penalty 93 Days
Delay Penalty per day $ 170,000.00
Total Delay Xxxxxxx - 000000 x 93 $15,810,000.00
2. MONTHLY CAPACITY BILLING; OUTAGES WITHIN ALLOWED LIMITS
Contracted Capacity = (CC) 500000 kW
Nominated Capacity = (NC) 500000 kW
Planned Outage for the month = 60 hours
Allowable Planned Outage for month = (Po) 60 hours
Unplanned Outage for the month = 12 hours
Allowable Unplanned outage for the month = (Uo) 12 hours
Total Hours in the month = (Ao) 720 hours
Measured Energy on HV side of transformer = (Em) 340000000 kWhr
Energy not delivered due to no fault of CEPA = (Eq) 0 kWhr
Reduced load as requested by NPC = (D) 0 kW
Number of hours dispatch order of NPC is in effect = (Td) 0 hours
Contract Capacity Rate for Basic Power Plant = (CCRp) 0.02300 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) US$ Component 0.0014 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) Peso Component 0.00033 Pesos/kWhr
Service Fee Rate for Basic Power Plant's return on Investment = (SFRp) 0.0023 $/kWhr
Contracted Energy for the month= (Ec) = CC x (Ao-Po-Uo)
= 500000x(720-60-12)
= 324000000 kWhr
Nominated Energy for the month= (En) = NC x (Ao-Po-Uo)
= 500000x(720-60-12)
= 324000000 kWhr
Undelivered Energy due to NPC's dispatch order= (Ed) = (NC-D) x Td
= (500000-0) x 0
= 0 kWhr
Energy Credit due to allowable Planned and Unplanned Outages (Eo) NC x (Uo +Po)
= 500000x(12+60)
= 36000000 kWhr
Adjusted Energy Generation= (Ea) = Em+Ed+Co+Eq
= 340000000+0+36000000+0
= 376000000 kWhr
(En+Eo)= 324000000+36000000
= 360000000 kWhr
As Ea > (En + Eo) then the value of (En+Eo) shall be used in place of Ea
Y is a variable:
If NC is greater than or equal to 0.95 x CC then Y=0
If NC less than 0.95 x CC then Y=1.
Therefore Y=0
A) CAPITAL COST RECOVERY FEE (A)
A=((CCRP X EA)-(Y x 1.05) x (CCRp)(Ec-En))
A=((0.023 x 360000000)-(0 x 1.05) x (0.023)(324000000-324000000)) = $8,280,000
B) FIXED OPERATING COST FEE (B)
I) US Dollar Component
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.0014 x 360000000)-(0 x 1.05) x (0.0014)(324000000-324000000)) = $504,000
II) PESO COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.00833 x 360000000)-(0 x 1.05) x (0.00833)(324000000-324000000)) = 2,998,800.00 Xxxxx
00
00
XXXXXXXXX XXXXXXXX
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
C) SERVICE FEE TO REFLECT RETURN OF INVESTMENTS (C)
C=((SFRp x Ea)-(Y x 1.05) x (SFRp)(Ec-En))
C=((0.0023 x 360000000)-(0 x 1.05) x (0.0023)(324000000-324000000))= $828,000
3. MONTHLY CAPACITY BILLING; OUTAGES OUTSIDE ALLOWED LIMITS
(Outage Allowance for the year already used)
Contracted Capacity = (CC) 500000 kW
Nominated Capacity = (NC) 500000 kW
Planned Outage for the month = 24 hours
Allowable Planned Outage for month = (Po) 0 hours
Unplanned Outage for the month = 12 hours
Allowable Unplanned outage for the month = (Uo) 0 hours
Total Hours in the month = (Ao) 720 hours
Measured Energy on HV side of transformer = (Em) 350000000 kWhr
Energy not delivered due to no fault of CEPA = (Eq) 0 kWhr
Reduced load as requested by NPC = (D) 0 kW
Number of hours dispatch order of NPC is in effect = (Td) 0 hours
Contract Capacity Rate for Basic Power Plant = (CCRp) 0.02300 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) US$ Component 0.0014 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) Peso Component 0.00833 Pesos/kWhr
Service Fee Rate for Basic Power Plant's return an investment = (SFRp) 0.0023 $/kWhr
Contracted Energy for the month = (Ec) = CC x (Ao-Po-Uo)
= 500000x(720-0-0)
= 360000000 kWhr
Nominated Energy for the month = (En) = NC x (Ao-Po-Uo)
= 500000x(720-0-0)
= 360000000 kWhr
Undelivered Energy due to NPC's dispatch order= (Ed) = (NC-D) x Td
(500000-0) x 0
= 0 kWhr
Energy Credit due to allowable Planned and Unplanned
Outages (Eo) = NC x (Uo +Po)
= 500000x(0+0)
= 0 kWhr
Adjusted Energy Generation= (Ea) = Em+Ed+Eo+Eq
= 350000000+0+0+0
= 350000000 kWhr
(En+Eo)= 360000000 + 0
= 360000000 kWhr
As Ea < (En + Eo) then the value of Ea shall be used.
Y is a variable:
If NC is greater than or equal to 0.95 x CC then Y=0
If NC less than 0.95 x CC then Y= 1 Therefore Y= 0
A) CAPITAL COST RECOVERY FEE (A)
A=((CCRp x Ea)-(Y x 1.05) x (CCRp) (Ec-En))
A=((0.023 x 350000000)-(0 x 1.05) x (0.023)(360000000-360000000)) $8,050,000
B) FIXED OPERATING COST FEE (B)
I) US DOLLAR COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.0014 x 350000000)-(0 x 1.05) x (0.00 14)(360000000-360000000))= $490,000
II) PESO COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.00833 x 350000000)-(0 x 1.05) x (0.00833)(360000000-360000000)) 2,915,500.00 Pesos
c) SERVICE FEE TO REFLECT RETURN OF INVESTMENTS (C)
87-A
95
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
C=((SFRp x Ea)-(Y x 1.05) x (SFRp)(Ec-En))
C=((0.0023 x 350000000)-(0 x 1.05) x (0.0023)(360000000-360000000))= $805,000
4. CALCULATION OF ENERGY FEES
A) TESTED NET PLANT HEAT RATE EQUAL TO GUARANTEED NET PLANT HEAT RATE
Measured Energy on HV side of transformer = (Em) 340000000 kWhr
Base Energy Rate per kilowatthour delivered (US$) = (BERd) 0.0017 $/kWhr
Base Energy Rate per kilowatthour delivered (Pesos) = (BERp) 0.00033 Pesos/kWhr
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (US$) = (Ud) 45.00 $/metric tonne
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (Pesos) = (Up) 1249.20 Pesos/metric tonne
Weighted Average of the Coal Higher Heating Value in the "as
received" basis basis of the last 3 purchases made by NPC prior to
the billing period = (HHV) 6200 kcal/kg
Guaranteed Net Plant Heat Rate at Rated Load = (HRg) 2288 kcal/kWhr
Tested Net Plant Heat Rate at Rated Load = (HRt) 2288 kcal/kWhr
Number of Hours in the Billing Period = (Ao) 720 hrs
ENERGY FEES FOR THE BILLING PERIOD (US$) (D)
D=Xx x XXXx + ((Ud x Em)/(1000 x HHV) x HRg-HRt))
D=340000000 x 0.0017 + ((45.00 x 340000000)/(1000 x 6200) x (2288-2288))
Energy Fees for Billing Period = $ 578,000
ENERGY FEES FOR THE BILLING PERIOD (PESOS) (D)
D=Em x BERp
D=340000000 x 0.00833
Energy Fees for Billing Period = 2,832,200.00 Pesos
B) TESTED NET PLANT HEAT RATE GREATER THAN GUARANTEED NET PLANT HEAT RATE
Measured Energy on HV side of transformer= (Em) 34000000 kWhr
Base Energy Rate per killowatthour delivered (US$) = (BERd) 0.0017 $/kWhr
Base Energy Rate per killowatthour delivered (Pesos) = (BERp) 0.00833 Pesos/kWhr
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (US$)= (Ud) 45.00 $/metric tonne
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (Pesos) = (Up) 1249.20 Pesos/metric tonne
Weighted Average of the Coal Higher Heating Value in the "as
received" basis basis of the last 3 purchases made by NPC prior to
the billing period = (HHV) 6200 kcal/kg
Guaranteed Net Plant Heat Rate at Rated Load = (HRg) 2288 kcal/kWhr
Tested Net Plant Heat Rate at Rated Load = (HRt) 2320 kcal/kWhr
Number of Hours in the Billing Period = (Ao) 720 hrs
Energy Fees for the Billing Period (US$) (D)
D=Xx x XXXx + ((Ud x Em) / (1000 x HHV) x (HRg-HRt))
D=340000000 x 0.0017 + ((45.00 x 340000000)/(1000 x 6200) x (2288-2320))
Energy Fees for Billing Period = $ 499,032
ENERGY FEES FOR THE BILLING PERIOD (PESOS) (D)
D=Em x BERp
D=340000000 x 0.00833
Energy Fees for Billing Period = 2,832,200.00 Pesos
C) TESTED NET PLANT HEAT RATE LESS THAN GUARANTEED NET PLANT HEAT RATE
Measured Energy on HV side of transformer = (EM) 340000000 kWhr
Base Energy Rate per killowatthour delivered (US$) = (BERd) 0.0017 $/kWhr
Base Energy Rate per killowatthour delivered (Pesos) = (BERp) 0.00833 Pesos/kWhr
87-B
96
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (US$) = (Ud) 45.00 $/metric tonne
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (Pesos) = (Up) 1249.20 Pesos/metric tonne
Weighted Average of the Coal Higher Heating Value in the "as
received" basis basis of the last 3 purchases made by NPC prior to
the billing period = (HHV) 6200 kcal/kg
Guaranteed Net Plant Heat Rate at Rated Load = (HRg) 2288 kcal/kWhr
Tested Net Plant Heat Rate at Rated Load = (HRt) 2254 kcal/kWhr
Number of Hours in the Billing Period = (Ao) 720 hrs
Energy Fees for the Billing Period (US$) (D)
D=Xx x XXXx + ((Ud x Em)/(1000 x HHV) x (HRg-HRt))
D=340000000 x 0.0017 + ((45.00 x 340000000)/(1000 x 6200) x (2288-2254))
Energy Fees for Billing Period = $ 661,903
Energy Fees for the Billing Period (Pesos) (D)
D=Em x BERp
D=340000000 x 0.00833
Energy Fees for Billing Period = 2,832,200.00 Pesos
5. MONTHLY CAPACITY BILLING; REDUCED
NOMINATED CAPACITY DUE TO
MANUFACTURING/MATERIAL DEFECT
Contracted Capacity = (CC) 500000 kW
Nominated Capacity = (NC) 468000 kW
Planned Outage for the month= 60 hours
Allowable Planned Outage for month = (Po) 60 hours
Unplanned Outage for the month = 12 hours
Allowable Unplanned outage for the month = (Uo) 12 hours
Total Hours In the month = (Ao) 720 hours
Measured Energy on HV side of transformer = (Em) 304000000 kWhr
Energy not delivered due to no fault of CEPA= (Eq) 0 kWhr
Reduced load as requested by NPC = (D) 0 kW
Number of hours dispatch order of NPC is in effect = (Td) 0 hours
Contract Capacity Rate for Basic Power Plant = (CCRp) 0.02300 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) US$ Component 0.0014 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) Peso Component 0.00833 Pesos/kWhr
Service Fee Rate for Basic Power Plant's return on investment = (SFRp) 0.0023 $/kWhr
Contracted Energy for the month = (Ec) = CC x (Ao-Po-Uo)
= 500000x(720-60-12)
= 324000000 kWhr
Nominated Energy for the month = (En) = NC x (Ao-Po-Uo)
= 468000x(720-60-12)
= 303264000 kWhr
Undelivered Energy due to NPC's dispatch order = (Ed) = (NC-D) x Td
= (468000-0) x 0
= 0 kWhr
Energy Credit due to allowable Planned and Unplanned Outages (Eo) = NC x (Uo + Po)
= 468000x(60+ 12)
= 33696000 kWhr
Adjusted Energy Generation = (Ea) = Em+Ed+Eo+Eq
= 304000000+0+33696000+0
= 337696000 kWhr
(En+Eo) = 303264000+33696000
= 336960000 kWhr
As Ea > (En + Eo) then the value of (En + Eo) shall be used.
Y is a variable:
If NC is greater than or equal to 0.95 x CC then Y=0
If NC less than 0.95 x CC then Y = 1 Therefore Y=1
87-C
97
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
A) CAPITAL COST RECOVERY FEE (A)
A=((CCRp x Ea)-(Y x 1.05) x (CCRp)(Ec-En))
A=((0.023 x 336960000)-(1 x 1.05) x (0.023)(324000000-303264000)) = $7,249,306
B) FIXED OPERATING COST FEE (B)
I) US DOLLAR COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.0014 x 336960000)-(l x 1.05) x (0.0014)(324000000-303264000)) = $441,262
II) PESO COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.00833 x 336960000)-(1 x 1.05) x (0.00833)(324000000-303264000)) = 2,625,509.38 Pesos
C) SERVICE FEE TO REFLECT RETURN OF INVESTMENTS (C)
C=((SFRp x Ea)-(Y x 1.05) x (SFRp)(Ec-En))
C=((0.0023 x 336960000)-(1 x 1.05) x (0.0023)(324000000-303264000)) = $724,931
6. CALCULATION OF INFRASTRUCTURE FEES
USING DATA FROM ITEM 2 ABOVE
Adjusted Energy Generation (Ea) 360000000 kWhr
Contracted Energy for the month (Ec) 324000000 kWhr
Nominated Energy for the month (En) 324000000 kWhr
Basic Infrastructure Fee (BIF) 0.00137 $/kWhr
Infrastructure Fee for Month- (BIF x Ea) -[1.05Y x BIF (Ec - En)]=
(0.00137 x 360000000)-[1.05x 0 x 0.00137 (324000000-324000000)]
Infrastructure Fee for month $493,200
7. EARLY COMPLETION INCENTIVE
Target Unit Completion Date June 30 1997
Actual Completion Date July 30 1998
Early Completion 30 days
7.1 EARLY COMPLETION BONUS (ARTICLE 3.16)
Contracted Capacity = (CC) 500000 kW
Nominated Capacity = (NC) 500000 kW
Planned Outage for the period = 60 hours
Allowable Planned Outage for period = (Po) 60 hours
Unplanned Outage for the period = 0 hours
Allowable Unplanned outage for the period = (Uo) 0 hours
Total Hours in the month = (Ao) 720 hours
Measured Energy on HV side of transformer = (Em) 340000000 kWhr
Energy not delivered due to no fault of CEPA = (Eq) 0 kWhr
Reduced load as requested by NPC = (D) 0 kW
Number of hours dispatch order of NPC is in effect = (Td) 0 hours
Contract Capacity Rate for Basic Power Plant = (CCRp) 0.02300 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) US$ Component 0.0014 $/kWhr
Contract Capacity Rate for Basic Power Plant's fixed operating cost = (OCRp) Peso Component 0.00833 Pesos/kWhr
Service Fee Rate for Basic Power Plants return on investment = (SFRp) 0.0023 $/kWhr
Contracted Energy for the period = (Ec)= CC x (Ao-Po-Uo)
= 500000x(720-60-0)
= 330000000 kWhr
Nominated Energy for the period = (En) = NC x (Ao-Po-Uo)
= 500000x(720-60-0)
= 330000000 kWhr
Undelivered Energy due to NPC's dispatch order= (Ed) = (NC - D) x Td
= (500000-0) X 0
= 0 kWhr
Energy Credit due to allowable Planned and Unplanned Outages (Eo) = NC x (Uo +Po)
87-D
98
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
= 500000x(0+60)
= 30000000 kWhr
Adjusted Energy Generation = (Ea) = Em+Ed+Eo+Eq
= 340000000+0+30000000+0
= 370000000 kWhr
(En+Eo)= 330000000+30000000
= 360000000 kWhr
As Ea > (En + Eo) then the value of (En+Eo) shall be used in place of Ea
Y is a variable:
If NC is greater than or equal to 0.95 x CC then Y=0
If NC less than 0.95 x CC then Y=1 Therefore Y = 0
A) CAPITAL COST RECOVERY FEE (A)
A=((CCRp x Ea)-(Y x 1.05) x (CCRp)(Ec-En))
A=((0.023 x 360000000)-(0 x 1.05) x (0.023)(330000000-330000000))= $8,280,000
B) SERVICE FEE TO REFLECT RETURN OF INVESTMENTS (C)
C=((SFRp x Ea)-(Y x 1.05) x (SFRp)(Ec-En))
C=((0.0023 x 360000000)-(0 x 1.05) x (0.0023)(330000000-330000000))= $828,000
C) INFRASTRUCTURE FEE
Basic Infrastructure Fee (BIF) 0.00137 $ per kWh
Infrastructure Fee for period=(BIF x Ea)-[1.05Y x BIF(Ec - En)]= (0.00137 x 360000000)- [1.05x 0 x 0.00137 x (330000000-330000000)]
Infrastructure Fee for period $493,200
7.2 CALCULATION OF FEES FOR PERIOD OF EARLY COMPLETION (ARTICLE 7.5b)
Using data from 7.1
Measured Energy on HV side of transformer= (Em) 340000000 kWhr
Base Energy Rate per kilowatthour delivered (US$)= (BERd) 0.0017 $/kWhr
Base Energy Rate per kilowatthour delivered (Pesos)= (BERp) 0.00033 Pesos/kWhr
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (US$)= (Ud)
45.00 $/metric tonne
Weighted Average of Coal Price (CIF) based on the average of the
last 3 purchases made by NPC prior to the billing period (Pesos)= (Up) 1249.20 Pesos/matric tonne
Weighted Average of the Coal Higher Heating Value in the "as
received" basis basis of the last 3 purchases made by NPC prior to
the billing period= (HHV) 6200 kcal/kWhr
Guaranteed Net Plant Heat Rate at Rated Load= (HRg) 2288 kcal/kWhr
Tested Net Plant Heat Rate at Rated Load= (HRt) 2200 kcal/kWhr
Number of Hours In the Billing Period= (Ao) 720 hrs
ENERGY FEES FOR THE BILLING PERIOD (US$) (D)
D=Xx x XXXx + ((Ud x Em)/(1000 x HHV) x (HRg-HRt))
D=340000000 x 0.0017 + ((45.00 x 340000000)/(1000 x 6200) x (2268-2200))
Energy Fees for Billing Period= $578,000
ENERGY FEES FOR THE BILLING PERIOD (PESOS)(D)
D=Em x BERp
D=340000000 x 0.00833
Energy Fees for Billing Period 2,832,200.00 Pesos
FIXED OPERATING COST FEE (B)
1) US Dollar Component
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
87-E
99
FIFTEENTH SCHEDULE
SAMPLE COMPUTATIONS OF MONTHLY BILLING, START-UP CHARGES, PENALTIES AND
INCENTIVES
B=((0.0014 x 360000000)-(0 x 1.05) x (0.0014)(330000000-330000000))= $504,000
II) PESO COMPONENT
B=((OCRp x Ea)-(Y x 1.05) x (OCRp)(Ec-En))
B=((0.00033 x 360000000)-(0 x 1.05) x (0.00033)(330000000-330000000))= 2,998,800.00 Pesos
00-X
000
XXXXXXXXX XXXXXXXX
Xxxxxx Xxxx and Specifications
LOCATION
The main access road shall be constructed from the main access gate of the Power
Station to the main national highway with approximate route as shown in the plan
at Exhibit I. Auxiliary access roads shall also be constructed from the main
access road to the Ash Disposal Sites as shown in the plan at Exhibit I. The
term "ACCESS ROAD" shall include such auxiliary access roads.
SPECIFICATION
The Access Road from the national highway to the Power Station shall be ten (10)
metres wide and concrete paved. The Access Road should be designed for speeds of
up to 60 kilometres per hour with traffic of 100 to 250 heavy vehicles per day.
The maximum gradient shall be 7%.
101
[MAP]
102
EXHIBIT II
(PROPOSED METER LOCATION)
SUAL THERMAL POWER PROJECT
LOCATION OF ELECTRICITY METERING POINTS
[CHART]
103
SIGNATURE PAGE
CEPA PANGASINAN ELECTRIC LIMITED
By: /s/ Xxxxxx Xx Xxxx Xxxxxx /s/ Xxxxxxx XX Xxxxxxx
----------------------------- ---------------------------
Xxxxxx Xx Ying Xxxxxx Xxxxxxx XX Xxxxxxx
in the presence of:
/s/ Xxxxx Xxx
---------------------------------
Xxxxx Xxx
NATIONAL POWER CORPORATION
By: /s/
------------------------------
in the presence of:
