EXHIBIT 10.1
OFFICE BUILDING LEASE
BETWEEN
24000 DEVELOPMENT LLC, A WASHINGTON LIMITED LIABILITY
COMPANY
LANDLORD
AND
EMULEX DESIGN & MANUFACTURING CORPORATION
TENANT
TABLE OF CONTENTS
Page
----
1. BASIC LEASE TERMS...................................................................................... 1
2. PREMISES AND EXTERIOR AREAS............................................................................ 3
(a) Premises...................................................................................... 3
(b) Mutual Covenants.............................................................................. 3
(c) Tenant's Use of Exterior Areas................................................................ 3
(d) Operation of Building and Exterior Areas...................................................... 4
3. TERM................................................................................................... 4
4. POSSESSION............................................................................................. 4
(a) Delivery of Possession........................................................................ 4
(b) Condition of Premises......................................................................... 4
(c) Delays in Delivery............................................................................ 4
5. RENT................................................................................................... 5
(a) Monthly Base Rent............................................................................. 5
(b) Late Payments................................................................................. 5
(c) Abatement..................................................................................... 5
(d) Abated Monthly Base Rent...................................................................... 6
6. OPERATING EXPENSES; REAL PROPERTY TAXES AND ASSESSMENTS; UTILITIES COSTS............................... 6
(a) Covenant to Pay............................................................................... 6
(b) Estimate Statement............................................................................ 6
(c) Reconciliation Statement...................................................................... 6
(d) Miscellaneous................................................................................. 6
(e) Audit Rights.................................................................................. 7
(f) Controllable Operating Expenses............................................................... 7
7. USE.................................................................................................... 7
(a) Tenant's Use of the Premises.................................................................. 7
(b) Compliance.................................................................................... 7
(c) Hazardous Materials........................................................................... 7
8. NOTICES................................................................................................ 9
9. BROKERS................................................................................................ 9
10. SURRENDER; HOLDING OVER................................................................................ 9
(a) Surrender..................................................................................... 9
(b) Holding Over.................................................................................. 9
11. TAXES ON TENANT'S PROPERTY; RENT TAX................................................................... 10
(i)
PAGE
----
(a) Taxes on Tenant's Property.................................................................... 10
(b) Rent Tax...................................................................................... 10
12. ALTERATIONS............................................................................................ 10
(a) Permitted Alterations......................................................................... 10
(b) Landlord's Approval........................................................................... 10
(c) Contractors................................................................................... 11
(d) Manner of Performance......................................................................... 11
(e) Ownership..................................................................................... 11
(f) Personal Property............................................................................. 11
13. REPAIRS................................................................................................ 11
(a) Landlord's Obligations........................................................................ 11
(b) Tenant's Obligations.......................................................................... 12
(c) Self-Help..................................................................................... 12
14. LIENS.................................................................................................. 12
15. ENTRY BY LANDLORD...................................................................................... 12
16. UTILITIES AND SERVICES................................................................................. 13
17. INSURANCE.............................................................................................. 13
(a) Tenant's Insurance............................................................................ 13
(b) Supplemental Tenant Insurance Requirements.................................................... 13
(c) Mutual Waiver of Parties...................................................................... 14
(d) Waiver of Insurers............................................................................ 14
(e) Landlord Insurance............................................................................ 14
(f) Blanket Insurance............................................................................. 14
18. DAMAGE OR DESTRUCTION.................................................................................. 14
(a) Partial Destruction........................................................................... 14
(b) Substantial Destruction....................................................................... 15
(c) Restoration Obligations....................................................................... 15
(d) Abatement of Rent............................................................................. 15
(e) Inability to Complete......................................................................... 15
(f) Damage Near End of Term....................................................................... 15
(g) Termination................................................................................... 15
(h) Subordination................................................................................. 16
19. EMINENT DOMAIN......................................................................................... 16
(a) Substantial Taking............................................................................ 16
(b) Partial Taking; Abatement of Rent............................................................. 16
(ii)
PAGE
----
(c) Condemnation Award............................................................................ 16
(d) Temporary Taking.............................................................................. 16
20. DEFAULTS AND REMEDIES.................................................................................. 16
(a) Defaults...................................................................................... 16
(b) Landlord's Remedies........................................................................... 17
(c) Landlord's Remedies; Performance for Tenant................................................... 17
(d) Late Payment.................................................................................. 17
(e) Rights and Remedies Cumulative................................................................ 18
21. LANDLORD'S DEFAULT..................................................................................... 18
22. ASSIGNMENT AND SUBLETTING.............................................................................. 18
(a) Restriction on Transfer....................................................................... 18
(b) Non-Transfers................................................................................. 19
(c) Transfer Notice............................................................................... 19
(d) Excess Rent................................................................................... 19
(e) Miscellaneous................................................................................. 19
(f) No Release.................................................................................... 20
(g) Costs......................................................................................... 20
(h) Landlord Cooperation.......................................................................... 20
23. SUBORDINATION.......................................................................................... 20
(a) Current Lienholders........................................................................... 20
(b) Future Liens.................................................................................. 20
(c) Attornment.................................................................................... 20
24. ESTOPPEL CERTIFICATE................................................................................... 21
(a) Tenant's Obligations.......................................................................... 21
(b) Tenant's Failure to Deliver................................................................... 21
(c) Landlord's Obligations........................................................................ 21
(d) Landlord's Failure to Deliver................................................................. 21
25. WAIVER................................................................................................. 22
26. PARKING................................................................................................ 22
27. FORCE MAJEURE.......................................................................................... 22
28. SIGNS.................................................................................................. 22
29. QUIET ENJOYMENT........................................................................................ 22
30. EXTENSION OPTIONS...................................................................................... 23
31. ROOFTOP COMMUNICATION EQUIPMENT........................................................................ 24
32. LANDLORD'S ACQUISITION OF LAND......................................................................... 24
(iii)
PAGE
----
(a) Purchase Agreement............................................................................ 24
(b) Property Materials............................................................................ 24
(c) Effectiveness................................................................................. 25
33. MISCELLANEOUS.......................................................................................... 25
(a) Keys.......................................................................................... 25
(b) Conflict of Laws.............................................................................. 25
(c) Successors and Assigns........................................................................ 25
(d) Attorneys' Fees............................................................................... 25
(e) Terms and Headings............................................................................ 25
(f) Time.......................................................................................... 25
(g) Prior Agreement; Amendments................................................................... 25
(h) Authority..................................................................................... 25
(i) Separability.................................................................................. 26
(j) Counterparts; Copy............................................................................ 26
(k) Landlord's Liability; Transfer................................................................ 26
(l) Financial Information......................................................................... 26
(m) Title 51 Waiver............................................................................... 27
(n) Arbitration................................................................................... 27
EXHIBITS:
A Legal Description of Land
B Work Letter Agreement
C Definition of Operating Expenses, Real Property Taxes and Assessments, and
Utilities Costs
D Standards for Utilities and Services
E Subordination, Non-Disturbance and Attornment Agreement
F-1 Tenant Estoppel Certificate
F-2 Landlord Estoppel Certificate
SCHEDULES:
D-1 Janitorial Specifications
(iv)
OFFICE BUILDING LEASE
This OFFICE BUILDING LEASE ("Lease") is entered into as of the 25th day of
August, 2005 (the "Effective Date") by and between 24000 Development LLC, a
Washington limited liability company ("Landlord"), and EMULEX DESIGN &
MANUFACTURING CORPORATION, a Delaware corporation ("Tenant") (collectively, the
"Parties").
1. BASIC LEASE TERMS. For purposes of this Lease, the following terms have the
following definitions and meanings:
(a) LANDLORD: 24000 Development LLC, a Washington limited liability company
(b) LANDLORD'S ADDRESS (FOR NOTICES):
0000 - 000xx Xxx XX
Xxxxxxxx, XX 00000
Attention: Xxxxxxx Xxxxxxxxxx
or such other place as Landlord may from time to time designate by notice to
Tenant.
(c) TENANT: Emulex Design & Manufacturing Corporation, a Delaware corporation.
(d) TENANT'S ADDRESS (FOR NOTICES):
Emulex Design & Manufacturing Corporation
0000 Xxxxx Xxxxxx
Xxxxx Xxxx, Xxxxxxxxxx 00000
Attention: Xxxxx Xxxxxxx, EVP HR and Facilities
In each case with a copy to
Emulex Corporation
0000 Xxxxx Xxxxxx
Xxxxx Xxxx, Xxxxxxxxxx 00000
Attention: Xxxxxxx Xxxx, Esq., General Counsel
or such other place as Tenant may from time to time designate by notice to
Landlord.
(e) BUILDING: An office building situated on land legally described in Exhibit
"A" attached hereto (the "Land") located at 00000 00xx Xxxxxx, in the City of
Bothell ("City"), County of Snohomish ("County"), State of Washington ("State").
(f) PREMISES: The entire Building and the Land. Prior to the Commencement Date,
JPC Architects, P.L.L.C. ("Tenant's Architect") shall certify in writing to
Landlord and Tenant the total rentable square feet of the Building, which shall
be calculated in accordance with the Standard Method for Measuring Floor Area in
Office Buildings (American National Standards Industry, Inc.) ANSI/BOMA
Z65.1-1996, as interpreted by Tenant's Architect. Tenant's Architect's
certification of the rentable square feet of the Building shall be binding on
Landlord and Tenant absent manifest error. Currently, Landlord estimates that
the Building contains 42,784 rentable square feet.
(g) TERM: Seventy-two (72) full calendar months, subject to possible extension
upon Tenant's exercise of its Extension Options in accordance with Section 30
below. The Lease Term shall expire on the last day of the calendar month which
is seventy-two (72) full calendar months after the
Commencement Date, subject to possible extension upon Tenant's exercise of its
Extension Options in accordance with Section 30 below.
(h) COMMENCEMENT DATE: The Commencement Date shall be the date on which Landlord
achieves Substantial Completion (as defined in the Work Letter Agreement
attached hereto as Exhibit "B" [the "Work Letter"]); provided, however, that the
Commencement Date shall be accelerated for Tenant Delays (as defined in the Work
Letter) in accordance with the Work Letter. This Lease shall be binding on the
parties as of the Effective Date. Landlord and Tenant currently anticipate that
Landlord will deliver possession of the Premises to Tenant, with the Tenant
Improvements (as defined in the Work Letter) Substantially Complete (as defined
in the Work Letter) on December 12, 2005 (the "Target Delivery Date").
(i) MONTHLY BASE RENT: "Monthly Base Rent" shall be:
Months 1 through and including 8*: $0 (abatement period), subject to adjustment as provided in
Section 1(l) below.
Months 9 through and including 47*: $1.50 per rentable square foot of the Building, calculated in
accordance with Section 1(f) above, per month during the initial Term
($18.00 per rentable square foot per year), subject to adjustment as
provided in Section 1(l) below.
Months 48 through and including 59*: $1.56 per rentable square foot of the Building, calculated in
accordance with Section 1(f) above, per month during the initial Term
($18.72 per rentable square foot per year), subject to adjustment as
provided in Section 1(l) below.
Months 59 through and including 71*: $1.62 per rentable square foot of the Building, calculated in
accordance with Section 1(f) above, per month during the initial Term
($19.47 per rentable square foot per year), subject to adjustment as
provided in Section 1(l) below.
* from and after the Commencement Date
As used in this Lease, the term "Rent" (or "rent") shall mean Monthly Base
Rent, plus all additional rent and other amounts due from Tenant under
this Lease.
(j) SECURITY DEPOSIT: There shall be no security deposit under this Lease.
(k) TENANT IMPROVEMENTS: All tenant improvements installed or to be installed
within the Premises to prepare the Premises for occupancy pursuant to the terms
of the Work Letter, except for Landlord's express covenants under this Lease and
all exhibits attached hereto.
(l) TENANT IMPROVEMENT ALLOWANCE: Forty and 19/100 ($40.19) per rentable square
foot of the Building, calculated in accordance with Section 1(f) above (the
"Initial Tenant Improvement Allowance"). In Tenant's sole and absolute
discretion, Tenant may elect to increase the Initial Tenant Improvement
Allowance by up to an additional Ten Dollars ($10.00) per rentable square foot
of the Building, calculated in accordance with Section 1(f) above (the
"Additional Tenant Improvement Allowance"), but only for the purpose of paying
TI Costs (as defined in the Work Letter), by the delivery of written notice of
such election delivered to Landlord on or before the Commencement Date. If the
Tenant obtains the Additional Tenant Improvement Allowance, the Monthly Base
Rent (starting on the Commencement Date, with no abatement) shall be increased
by an amount equal to the amount of the Additional Tenant Improvement
-2-
Allowance paid by Landlord to Tenant, amortized over seventy-two months using an
interest factor of six percent (6%). (By way of example, if the Additional
Tenant Improvement Allowance is $427,840 ($10.00 times 42,784 rentable square
feet), then the Monthly Base Rent shall be increased by $7,090.54 each month,
for seventy-two months, commencing on the Commencement Date.) The Tenant
Improvement Allowance shall be disbursed in accordance with the Work Letter. Any
portion of the Tenant Improvement Allowance not disbursed or used by the date
which is ninety (90) days after the Commencement Date shall be paid by Landlord
to Tenant at that time.
(m) PERMITTED USE: General office use and any other legally permitted uses under
applicable laws, regulations, ordinances and codes applicable to the use and
occupancy of the Premises (collectively, "Laws").
(n) PARKING: All parking located on the Land shall be for the exclusive use of
Tenant and its agents, contractors, employees, representatives, invitees,
licensees, subtenants and assignees, free of charge during the Term of this
Lease.
(o) BROKER(s): Washington Partners, Inc. and Xxxxxxx, Inc., representing Tenant.
No Broker representing Landlord.
(p) INTEREST RATE: shall mean twelve percent (12%) per annum.
(q) EXHIBITS: Exhibits "A" through "F-2", inclusive, which Exhibits are attached
to this Lease and incorporated herein by this reference.
(r) TENANT PARTIES: Tenant and/or any of Tenant's agents, contractors,
employees, representatives, subtenants and assignees.
(s) LANDLORD PARTIES: Landlord and/or any of Landlord's agents, contractors,
employees, and representatives.
This Section 1 represents a summary of the basic terms and definitions of this
Lease. In the event of any inconsistency between the terms contained in this
Section 1 and any specific provision of this Lease, the terms of the more
specific provision shall prevail.
2. PREMISES AND EXTERIOR AREAS.
(a) PREMISES. Landlord hereby leases to Tenant and Tenant hereby leases from
Landlord the Premises as improved or to be improved with the Tenant Improvements
described in the Work Letter. Tenant shall have entry access to the Building and
access to the Premises twenty-four (24) hours per day, seven (7) days per week
year-round.
(b) MUTUAL COVENANTS. Landlord and Tenant agree that the letting and hiring of
the Premises is upon and subject to the terms, covenants and conditions
contained in this Lease and each party covenants as a material part of the
consideration for this Lease to keep and perform their respective obligations
under this Lease.
(c) TENANT'S USE OF EXTERIOR AREAS. During the Term of this Lease, Tenant and
the Tenant Parties shall have the nonexclusive right to use in common with
Landlord, subject to the terms of this Lease, the Building, the Land and the
following:
(i) All exterior areas situated on the Land, including, without
limitation, the Land's parking facilities (the "Parking Areas"), trash areas,
roadways, sidewalks, walkways, parkways, driveways, landscaped areas, plaza
areas, outdoor eating areas, fountains and similar areas and facilities
(collectively, "Exterior Areas").
-3-
(ii) Any available conduits in the Building and elsewhere on the Land and
the right to install and maintain conduits, cabling and/or wiring within such
conduits and other conduit and risers previously installed in the Building and
elsewhere on the Land for such purposes or in other commercially feasible
locations reasonably approved by Landlord for power and telecommunications
purposes.
(iii) Any currently existing facilities bringing water and other utilities
to the Building and the right to install and maintain additional utility
conveyance facilities elsewhere in the Building or on the Land in other
commercially feasible locations reasonably approved by Landlord.
(d) OPERATION OF BUILDING AND EXTERIOR AREAS. Landlord shall operate and
maintain the Building and Exterior Areas in accordance with the standards and
specifications ("Maintenance Standards") set forth in this Lease and Exhibit "D"
attached hereto (including Schedules "D-1" through "D-4", inclusive).
Notwithstanding the foregoing, at any time during the Term, Tenant may elect, by
the delivery of written notice ("Tenant's Repair Election") to Landlord, to
perform the repair, maintenance and upkeep of the Building and the Exterior
Areas to be performed by Landlord hereunder. Such repair, maintenance and upkeep
shall be in accordance with the Maintenance Standards, and at Tenant's sole cost
and expense. Tenant's Repair Election shall become effective on the later of (i)
the date specified in Tenant's notice of the exercise of Tenant's Repair
Election or (ii) the first day of a calendar month, which is at least one full
calendar month after the delivery of Tenant's Repair Election. If Tenant
thereafter wishes to return to Landlord the obligation to perform repair,
maintenance and upkeep, the obligation shall be returned to Landlord no earlier
than the first day of a calendar month which is at least one full calendar month
after the date that Tenant provides written thereof to notice to Landlord. If
Tenant exercises Tenant's Repair Election, then Operating Expenses reimbursed by
Tenant to Landlord pursuant to Section 6 shall not include costs for work
performed, and/or services provided, by Tenant from and after the effective date
of Tenant's Repair Election.
3. TERM. The term of this Lease ("Term") will be for the period designated in
Section 0, commencing on the Commencement Date, plus any extensions of the Term
pursuant to any provision of this Lease or any future amendment of this Lease.
Once the Commencement Date occurs, the Parties, and the request of either party,
shall sign a written confirmation of the Commencement Date.
4. POSSESSION.
(a) DELIVERY OF POSSESSION. Landlord shall use commercially reasonable efforts
to deliver possession of the Premises (and keys thereto) to Tenant, with the
Tenant Improvements Substantially Complete, on or before the Target Delivery
Date. Notwithstanding any entry, use or occupancy of the Premises by Tenant
prior to the Commencement Date, Tenant shall not have any obligation to pay
Monthly Base Rent, Operating Expenses, Real Property Taxes and Assessments or
Utilities Costs until the Commencement Date, at which time such obligations
shall begin to accrue.
(b) CONDITION OF PREMISES. Landlord hereby represents and warrants to Tenant
that the Premises, the Building (including without limitation all Building
systems) and all Exterior Areas, as of the date Landlord delivers possession of
the Premises to Tenant with the Tenant Improvements Substantially Complete,
shall be (i) in material compliance with all applicable Laws in effect as of the
date of this Lease, including, without limitation, the Americans with
Disabilities Act and all related state and local access laws, regulations and
requirements (the "ADA"), local building codes and local fire/life/safety codes,
and (ii) in good and working order. Landlord, at its sole cost and expense,
shall be responsible for correcting (x) any latent defects in the structural
portions of the Building, (y) any breaches of Landlord's covenants,
representations and warranties set forth in this Section or elsewhere in this
Lease or the Work Letter. Subject to Landlord's covenants imposed by this
Section 4(b), elsewhere in this Lease and the Work Letter, Tenant shall accept
the Premises in its "as is" condition upon delivery by Landlord.
(c) DELAYS IN DELIVERY. If the Commencement Date has not occurred by December
19, 2005, then the Commencement Date may not occur until on or after January 9,
2006. If the Commencement Date has not occurred on or before February 1, 2006,
then Landlord shall pay to Tenant "DELAY DAMAGES" equal to the "holdover amount"
payable by Tenant to the landlord under Tenant's lease in the Bothell
-4-
North Creek area ("CURRENT SPACE"). The "holdover amount" shall mean (i) the
difference between (A) the monthly base rental rate (on a per rentable square
foot basis) paid by Tenant to its landlord for the use of the Current Space
after February 1, 2006 and (B) the monthly base rental rate (on a per rentable
square foot basis) paid by Tenant to its landlord for the use of the Current
Space immediately prior to the scheduled expiration date of Tenant's lease of
the Current Space, multiplied by (ii) the number of rentable square feet of the
Current Space. If the Commencement Date has not occurred on or before June 1,
2006, then Tenant may terminate this Lease by giving ten (10) days' prior
written notice to Landlord of such intent to terminate, and if the Commencement
Date has not occurred on or before the expiration of such ten (10) day period,
this Lease shall terminate, and Tenant shall retain a claim against Landlord for
damages constituting Tenant's actual costs incurred in connection with this
Lease and/or as a result of Landlord's failure to achieve Substantial Completion
by June 1, 2006, (Landlord shall not in any event be liable for lost revenues,
profits, or business opportunities, or incidental or consequential damages of
any kind). Notwithstanding the foregoing, the February 1 and the June 1 dates in
this Section 4(c) shall be extended on a day for day basis for Permit Delays (as
defined in the Work Letter) in accordance with the Work Letter.
5. RENT.
(a) MONTHLY BASE RENT. Tenant agrees to pay Landlord the Monthly Base Rent for
the Premises in advance on the first day of each calendar month during the Term
without prior notice or demand. If the Term of this Lease commences on a day
other than the first day of a calendar month, then the rent for such period will
be prorated in the proportion that the number of days this Lease is in effect
during such period bears to the number of days in such month. The obligation to
pay Rent is absolute and unconditional, and shall not at any time be subject to
offset, discount, or reduction of any kind whatsoever, except as specifically
provided in this Lease.
(b) LATE PAYMENTS. Late payments of Monthly Base Rent and/or any item of
additional rent will be subject to interest and a late charge as provided in
Section 20(d) below.
(c) ABATEMENT. Notwithstanding anything to the contrary contained in this Lease,
in the event Tenant's use of all or a material part of the Building is
materially impaired, for any reason other than the acts or omissions of Tenant
or any of the Tenant Parties, such that the disruption materially and adversely
interferes with the conduct of Tenant's business in the Building for three (3)
consecutive business days after written notice from Tenant to Landlord or ten
(10) days after written notice from Tenant to Landlord in any twelve (12) month
period (such three (3) consecutive business day period or ten (10) day period
after written notice from Tenant to Landlord, as applicable, is referred to
herein as the "Eligibility Period"), due to (i) an interruption of utility or
mechanical services to the Building (A) caused by the negligence or misconduct
of a Landlord Party, or (B) which is covered by Landlord's rental loss insurance
policy, (ii) an inability to access the Building or Parking Areas (A) due to
actions of a Landlord Party, or (B) which is covered by Landlord's rental loss
insurance policy, (iii) the performance of repairs, maintenance or other work
required to be made to the Building which are the responsibility of Landlord
under this Lease or which otherwise are performed by or on behalf of Landlord,
and/or (iv) Landlord's failure to perform repairs, maintenance or other work
required to be made to the Building which are the responsibility of Landlord
under this Lease or which otherwise are performed by or on behalf of Landlord,
then Tenant shall be entitled to an equitable abatement of Monthly Base Rent
under this Lease based upon the portion of the Building affected thereby
(provided that if the operation of Tenant's business from the remainder of the
Building not affected thereby is not reasonably practicable under the
circumstances and Tenant in fact does not operate for business from the
remainder of the Building, all Monthly Base Rent (but not additional rent) under
this Lease shall be subject to such abatement) from the commencement of the
Eligibility Period until the applicable material impairment is cured. The
provisions of this Section 5(d) shall not, however, apply in the event of a
casualty governed by the provisions of Section 18 below or in the event of a
taking or condemnation governed by the provisions of Section 19 below. No
abatement of rent shall apply to any portion of the Building which is not
physically occupied and actually used by the Tenant during the Eligibility
Period.
-5-
(d) ABATED MONTHLY BASE RENT. Notwithstanding anything in this Lease to the
contrary, Tenant's installments of Monthly Base Rent (but not any additional
rent or other payments or amounts due) for the first eight (8) full calendar
months of the Term shall be abated in full.
6. OPERATING EXPENSES; REAL PROPERTY TAXES AND ASSESSMENTS; UTILITIES COSTS.
(a) COVENANT TO PAY. In addition to Monthly Base Rent, commencing on the
Commencement Date, Tenant agrees to pay Landlord as additional rent in
accordance with the terms of this Section 6, determined on an annual basis, but
payable monthly as provided herein, Operating Expenses, Real Property Taxes and
Utilities Costs attributable to the Premises. "Operating Expenses," "Real
Property Taxes and Assessments," and "Utilities Costs" shall have the meanings
set forth in Exhibit "C" hereto.
(b) ESTIMATE STATEMENT. Commencing on the Commencement Date, and from time to
time thereafter during the Term of this Lease, Landlord may deliver to Tenant a
statement ("Estimate Statement") wherein Landlord will estimate some or all of
the Operating Expenses, Real Property Taxes and Assessments, and Utilities Costs
attributable to the Premises for the then current calendar year. Tenant agrees
to pay Landlord, as additional rent, one-twelfth (1/12th) of the estimated
Operating Expenses, Real Property Taxes and Assessments and Utilities Costs
pursuant to the most recently delivered Estimate Statement each month
thereafter, beginning with the next installment of rent due, until such time as
Landlord issues a revised Estimate Statement; except that, (i) concurrently with
the regular monthly rent payment next due following the receipt of each such
revised Estimate Statement, Tenant agrees to pay Landlord an amount equal to one
monthly installment of any amounts by which the revised Estimate Statement
exceeds the prior Estimate Statement (less any applicable Operating Expenses,
Real Property Taxes and Assessments, and/or Utilities Costs already paid)
multiplied by the number of months from the beginning of the applicable calendar
year to the month of such rent payment next due, all months inclusive, (ii)
Landlord shall not provide Tenant with revised Estimate Statements more than one
time in any calendar year of the Term, and (iii) if Landlord delivers a revised
Estimate Statement later than the twentieth (20th) day of a calendar month, then
such revised Estimate Statement shall not be effective until the first day of
the second calendar month after delivery.
(c) RECONCILIATION STATEMENT. Within one hundred twenty (120) days after the end
of each calendar year during the Term of this Lease, Landlord will deliver to
Tenant a statement ("Reconciliation Statement") which states the actual amounts
incurred by Landlord for Operating Expenses, Real Property Taxes and
Assessments, and Utilities Costs for the preceding calendar year. If the
Reconciliation Statement reveals that the actual Operating Expenses, Real
Property Taxes and Assessments, and Utilities Costs are more than the total
additional rent paid by Tenant for Operating Expenses, Real Property Taxes and
Assessments, and Utilities Costs on account of the preceding calendar year,
Tenant agrees to pay Landlord the difference in a lump sum within thirty (30)
days of receipt of the Reconciliation Statement. If the Reconciliation Statement
reveals that the actual Operating Expenses, Real Property Taxes and Assessments,
and Utilities Costs are less than the additional rent paid by Tenant for
Operating Expenses, Real Property Taxes and Assessments, and Utilities Costs on
account of the preceding calendar year, Landlord will credit any overpayment
toward the next monthly installments of Operating Expenses, Real Property Taxes
and Assessments, and Utilities Costs due under this Lease; provided however, if
such excess exceeds $10,000 or this Lease has expired or terminated, Landlord
will promptly refund any such overpayment to Tenant.
(d) MISCELLANEOUS. Even though the Term has expired and Tenant has vacated the
Premises, when the final determination is made of the actual Operating Expenses,
Real Property Taxes and Assessments, and Utilities Costs for the year in which
this Lease terminates (which shall occur if at all within 120 days of the
expiration of the calendar year in which Lease termination occurs), Tenant
agrees to promptly pay any increase due over the estimated amounts paid and,
conversely, any overpayment made in the event said amounts decrease shall
promptly be rebated by Landlord to Tenant or offset against the Monthly Base
Rent coming due pursuant to this Lease. Such obligation will be a continuing one
which will survive the expiration or earlier termination of this Lease.
-6-
(e) AUDIT RIGHTS. Tenant and its duly authorized representatives or any
certified public accountant selected by Tenant shall have the right to audit the
records of Landlord related to Operating Expenses, Real Property Taxes and
Assessments and Utilities Costs. Any such audit shall be performed, if at all,
within six (6) months after receipt of the applicable Reconciliation Statement
for a calendar year. Any audit hereunder shall be upon not less then ten (10)
days' prior written notice to Landlord, during normal business hours at the
Building. Tenant may review and photocopy, at Tenant's expense, reasonable
documentation supporting Operating Expense, Real Property Tax and Assessment and
Utilities Cost items under review. If Tenant's Percentage of actual Operating
Expenses, Real Property Taxes and Assessments and Utilities Costs are determined
to have been overstated by Landlord for any calendar year in excess of one
percent (1%), Landlord shall reimburse Tenant for the reasonable cost of
Tenant's audit within thirty (30) days following Tenant's submission to Landlord
of reasonable evidence of the amount of such costs; provided, however, that such
reimbursement shall not exceed the amount of the overcharge. Tenant's payment of
Operating Expenses, Real Property Taxes and Assessments and Utilities Costs in
accordance with Landlord's Estimate Statements or Reconciliation Statements
shall not constitute a waiver of any right to audit and/or dispute such expenses
as set forth herein.
(f) CONTROLLABLE OPERATING EXPENSES. Notwithstanding anything in this Lease or
Exhibit "C" attached hereto to the contrary, Tenant shall not be liable to
Landlord for any aggregate increase in Controllable Operating Expenses (defined
below) in excess of four percent (4%) over the Controllable Operating Expenses
paid in the prior calendar year, with such excess to be borne by Landlord at
Landlord's sole cost and expense. As used herein, "Controllable Operating
Expenses" shall mean Operating Expenses which can be reasonably controlled by
Landlord and shall not include insurance costs, Real Property Taxes and
Assessments or Utilities Costs. Operating Expenses shall not be deemed to be
"Controllable Operating Expenses" if Landlord exercises reasonable efforts to
obtain competitive bids for the Operating Expense items in question and is not
able to obtain a lower bid from a reasonably qualified contractor or service
provider, for the same quality and quantity of items or services; provided,
however, if Landlord fails to seek bids for an Operating Expense item that is
likely to result in bids of varying prices, or if Landlord bids out work for an
Operating Expense item and Landlord does not select the lowest bid from a
reasonably qualified contractor or service provider, for the same quality and
quantity of items or services, then such Operating Expenses shall be deemed to
be Controllable Operating Expenses.
7. USE.
(a) TENANT'S USE OF THE PREMISES. The Premises may be used for the use or uses
set forth in Section 1(m) only, and Tenant will not use or permit the Premises
to be used for any other purpose without the prior written consent of Landlord,
which consent Landlord shall not unreasonably withhold, condition or delay.
(b) COMPLIANCE. At Tenant's sole cost and expense, Tenant agrees to procure,
maintain all governmental licenses, insurance and permits required for the
proper and lawful conduct of Tenant's business from the Premises, if any. Tenant
agrees not to use, alter or occupy the Premises or allow the Premises to be
used, altered or occupied in violation of, and Tenant, at its sole cost and
expense, agrees to use and occupy the Premises in compliance with: (i) subject
to Landlord's covenants under this Lease, any and all applicable laws,
ordinances, rules and regulations ("Laws"), and (ii) the requirements of the
Board of Fire Underwriters and any other similar body. Tenant agrees not to
cause, maintain or permit any nuisance or waste in, on, under or about the
Premises. No obligation of Tenant to comply with Laws shall require Tenant to
make any alterations, additions or improvements to the systems or structure of
the Building or any areas outside the Premises, which obligation shall be
performed by Landlord at its sole cost and expense; provided, however, Tenant
shall construct the Tenant Improvements pursuant to the Work Letter in
compliance with all applicable Laws (including the ADA).
(c) HAZARDOUS MATERIALS
(i) TENANT HAZARDOUS MATERIALS REQUIREMENTS. Except for ordinary office
and equipment supplies typically used in the ordinary course of business within
office buildings, such as copier toner,
-7-
liquid paper, glue, ink and common household cleaning materials (some or all of
which may constitute "Hazardous Materials" as defined in this Lease and are
referred to hereinafter as the "Permitted Substances"), Tenant agrees not to
cause or permit any Hazardous Materials to be brought upon, stored, used,
handled, generated, released or disposed of on, in, under or about the Premises,
the Building or the Land by Tenant or the Tenant Parties, without the prior
written consent of Landlord, which consent Landlord may withhold in its sole and
absolute discretion. All use of Hazardous Materials by a Tenant Party shall be
in compliance with all Environmental Laws.
(ii) LANDLORD HAZARDOUS MATERIALS REQUIREMENTS. Landlord represents and
warrants to Tenant that, to Landlord's actual knowledge, there are no Hazardous
Material(s) which are, or have previously been, located in, or about the
Building, the Exterior Areas or the Land; except as disclosed in the August 15,
2005, Phase I Environmental Assessment prepared by Environmental Associates,
Inc., a copy of which has been provided to Tenant. Landlord, at its sole cost
and expense, shall be responsible for the removal of any Hazardous Materials
located in or about the Building or Land as of date that possession of the
Premises is delivered to Tenant, to the extent that removal is required by the
Environmental Laws or to the extent that the presence of such Hazardous
Materials (even if in compliance with Environmental Laws) would materially
adversely affect Tenant's use and occupancy of the Building pursuant to this
Lease. Except for Permitted Substances, and except as may be in compliance with
applicable Environmental Laws, Landlord agrees not to cause or knowingly permit
any Hazardous Materials to be brought upon, stored, used, handled, generated,
released or disposed of on, in, under or about the Premises, the Building, the
Exterior Areas or any other portion of the Land by Landlord Parties"). Further,
Landlord's cost of the removal of Hazardous Materials in the Building or in any
other location on the Land shall be excluded from an Operating Expenses that
would be passed through to Tenant.
(iii) HAZARDOUS MATERIALS INDEMNITIES. To the fullest extent permitted by
law, Tenant agrees to promptly indemnify, protect, defend and hold harmless
Landlord and Landlord's partners, officers, members, directors, employees and
agents (collectively, "Landlord Indemnified Parties") from and against any and
all claims, damages, judgments, suits, causes of action, losses, liabilities,
penalties, fines, expenses and costs (including, without limitation, clean-up,
removal, remediation and restoration costs, sums paid in settlement of claims,
attorneys' fees, consultant fees and expert fees and court costs) which arise or
result from Hazardous Materials released on, in, under or about the Premises,
the Building or the Land by Tenant Parties. Tenant agrees to promptly notify
Landlord of any release of Hazardous Materials at the Premises, the Building or
any other portion of the Land which Tenant becomes aware of during the Term of
this Lease, whether caused by Tenant or any other persons or entities. To the
fullest extent permitted by law, Landlord agrees to promptly indemnify, protect,
defend and hold harmless Tenant and Tenant's partners, officers, directors,
employees, agents, successors and assigns (collectively, "Tenant Indemnified
Parties") from and against any and all claims, damages, judgments, suits, causes
of action, losses, liabilities, penalties, fines, expenses and costs (including,
without limitation, clean-up, removal, remediation and restoration costs, sums
paid in settlement of claims, reasonable attorneys' fees, consultant fees and
expert fees and court costs) which arise or result from the presence of
Hazardous Materials on, in, under or about the Premises, the Building or any
other portion of the Land which exist prior to the Actual Delivery Date or which
are caused by Landlord or any Landlord Parties.
(iv) HAZARDOUS MATERIALS. As used in this Lease, the term "Hazardous
Materials" shall mean and include any chemical, substance, material, controlled
substance, object, condition, waste, living organism or combination thereof,
whether solid, semi-solid, liquid or gaseous, which is or may be hazardous to
human health or safety or to the environment due to its radioactivity,
ignitability, corrosivity, reactivity, explosivity, toxicity, carcinogenicity,
mutagenicity, phytotoxicity, infectiousness or other harmful or potentially
harmful properties or effects, including, without limitation, tobacco smoke,
petroleum and petroleum products, asbestos, radon, polychlorinated biphenyls
(PCBs), refrigerants (including those substances defined in the Environmental
Protection Agency's "Refrigerant Recycling Rule," as amended from time to time)
and all of those chemicals, substances, materials, controlled substances,
objects, conditions, wastes, living organisms or combinations thereof which are
now or become in the future listed, defined or regulated in any manner by any
Environmental Law based upon, directly or indirectly, such
-8-
properties or effects. As used herein, "Environmental Laws" means any and all
federal, state or local environmental, health and/or safety-related laws,
regulations, standards, decisions of courts, ordinances, rules, codes, orders,
decrees, directives, guidelines, permits or permit conditions, currently
existing and as amended, enacted, issued or adopted in the future which are or
become applicable to Tenant, the Premises or the Land.
(v) SURVIVAL. The provisions of this Section 7(c) shall survive the
expiration of earlier termination of this Lease.
8. NOTICES. Any notice required or permitted to be given hereunder must be in
writing and may be given by personal delivery (including delivery by overnight
courier or an express mailing service) or by mail, if sent by registered or
certified mail. Notices to Tenant shall be sufficient if delivered to Tenant at
the address designated in Section 1(d) and notices to Landlord shall be
sufficient if delivered to Landlord at the address designated in Section 1(b).
Either party may specify a different address for notice purposes by written
notice to the other. Notice shall be deemed to be delivered upon the earlier of
(a) actual receipt or refusal of delivery or (b) (i) if by overnight courier or
express mailing service, one (1) business day after deposit with delivery
expenses prepared and addressed as provided above or (ii) five (5) business days
after deposit with the U.S. Postal Service, postage prepaid and addressed as
provided above.
9. BROKERS. The Parties acknowledge that the brokers who negotiated this Lease
are stated in Section 1(o) (the "Brokers"). Landlord shall be responsible for
the commissions payable to such brokers in connection with this Lease in
accordance with separate commission agreements between Landlord and such
brokers. Each party represents and warrants to the other, that, to its
knowledge, no other broker, agent or finder (a) negotiated or was instrumental
in negotiating or consummating this Lease on its behalf, and (b) is or might be
entitled to a commission or compensation in connection with this Lease. Landlord
shall promptly indemnify, protect, defend and hold Tenant harmless from and
against any and all claims, damages, judgments, suits, causes of action, losses,
liabilities, penalties, fines, expenses and costs (including attorneys' fees and
court costs) in connection with (i) any failure or alleged failure by Landlord
to pay commissions payable to the Brokers, (ii) any failure or alleged failure
by Landlord to pay fees or commissions related to with Landlord's acquisition of
the Land and/or (iii) any broker, agent or finder alleging representation of or
agreement with Landlord in connection with this Lease. Tenant shall promptly
indemnify, protect, defend and hold Landlord harmless from and against any and
all claims, damages, judgments, suits, causes of action, losses, liabilities,
penalties, fines, expenses and costs (including attorneys' fees and court costs)
that may be asserted or brought by any broker, agent or finder alleging
representation of or agreement with Tenant in connection with this Lease. The
foregoing indemnities shall survive the expiration or earlier termination of
this Lease.
10. SURRENDER; HOLDING OVER.
(a) SURRENDER. The voluntary or other surrender of this Lease by Tenant, or a
mutual cancellation thereof, shall not constitute a merger, and shall, at the
option of Landlord, operate as an assignment to Landlord of any or all subleases
or subtenancies. Upon the expiration or earlier termination of this Lease,
Tenant agrees to peaceably surrender the Premises to Landlord broom clean, with
data and telecommunications wiring and cabling in place, and in reasonably good
repair and condition, ordinary wear and tear and casualty damage excepted, with
all of Tenant's personal property removed from the Premises and all damage
caused by such removal repaired. The delivery of keys to any employee of
Landlord or to Landlord's agent or any employee thereof alone will not be
sufficient to constitute a termination of this Lease or a surrender of the
Premises.
(b) HOLDING OVER. Tenant will not be permitted to hold over possession of the
Premises after the expiration or earlier termination of the Term without the
express written consent of Landlord, which consent Landlord may withhold in its
sole and absolute discretion. If Tenant holds over after the expiration or
earlier termination of the Term, Landlord may, at its option, treat Tenant as a
tenant at sufferance only, and such continued occupancy by Tenant shall be
subject to all of the terms, covenants and conditions of this Lease, so far as
applicable, except that the Monthly Base Rent for any such
-9-
holdover period shall be (i) the same Monthly Base Rent in effect under this
Lease immediately prior to such holdover during the first ninety (90) days of
holdover, and (ii) thereafter one hundred fifty percent (150%) of the Monthly
Base Rent in effect under this Lease immediately prior to such holdover.
Notwithstanding anything in this Lease to the contrary, Tenant shall not be
liable for any consequential, punitive or other damages caused by the first
ninety (90) days of any holdover, but if Tenant fails to surrender the Premises
within ninety (90) days after the expiration of this Lease in accordance with
the terms of this Section 10(b) despite demand to do so by Landlord, Tenant
agrees to promptly indemnify, protect, defend and hold Landlord harmless from
all claims, damages, judgments, suits, causes of action, losses, liabilities,
penalties, fines, expenses and costs (including attorneys' fees and costs),
including, without limitation, costs and expenses incurred by Landlord in
returning the Premises to the condition in which Tenant was to surrender it and
claims made by any succeeding tenant founded on or resulting from Tenant's
failure to surrender the Premises. The provisions of this Section 10(b) will
survive the expiration or earlier termination of this Lease.
11. TAXES ON TENANT'S PROPERTY; RENT TAX.
(a) TAXES ON TENANT'S PROPERTY. Tenant agrees to pay before delinquency, all
taxes and assessments (real and personal) levied against any personal property,
trade fixtures or Alterations placed by Tenant in or about the Premises
(including any increase in the assessed value of the Premises based upon the
value of any such personal property or trade fixtures). If any such taxes or
assessments are levied against Landlord or Landlord's property, Landlord may,
after written notice to Tenant (and under proper protest if requested by Tenant)
pay such taxes and assessments, in which event Tenant agrees to reimburse
Landlord all amounts paid by Landlord within ten (10) business days after demand
by Landlord; provided, however, Tenant, at its sole cost and expense, will have
the right, with Landlord's cooperation, to bring suit in any court of competent
jurisdiction to recover the amount of any such taxes and assessments so paid
under protest.
(b) RENT TAX. Tenant shall pay to Landlord as additional rent, any tax ("RENT
TAX") upon Rent payable under this Lease or any tax or fee in any form payable
by Landlord because of or measured by receipts or income of Landlord derived
from this Lease. The preceding sentence shall not apply to general income tax or
business and occupation tax of Landlord, except to the extent a Rent Tax is
imposed as a business and occupation tax. If a Rent Tax imposed on a monthly
basis as Rent is due, then such Rent Tax shall be payable monthly on the first
day of each calendar month; provided, however, that the first payment shall be
due no sooner than thirty (30) days after written notice from Landlord, and each
change in the amount due shall require thirty (30) days written notice prior to
the change.
12. ALTERATIONS. After installation of the initial Tenant Improvements for the
Premises pursuant to Exhibit "B", Tenant may, at its sole cost and expense, make
alterations, additions, improvements and decorations (including, without
limitation, wall coverings, window coverings, floor coverings and other
finishes) to the Premises (collectively, "Alterations") subject to and upon the
following terms and conditions:
(a) PERMITTED ALTERATIONS. Except for Permitted Alterations, Tenant shall not
perform any Alterations in the Premises or the Land without the prior written
consent of Landlord, which shall not be unreasonably withheld, conditioned or
delayed. Notwithstanding the foregoing, Tenant may without the prior written
consent of Landlord, but upon prior notice to Landlord, replace carpeting, floor
coverings and/or wall coverings; repaint walls; and make other Alterations that
do not (i) materially and adversely affect the Building's structure, equipment,
services or systems, or the proper functioning thereof; (ii) materially and
adversely affect the outside appearance or character of the Building; or (iv)
cost more than the greater of $2.50 per square foot or One Hundred Thousand and
No/100ths Dollars ($100,000.00) per project (exclusive of the cost of carpeting,
painting, floor coverings and/or wall coverings) (collectively, "Permitted
Alterations").
(b) LANDLORD'S APPROVAL. Before proceeding with any Alterations other than
Permitted Alterations, Tenant must first obtain Landlord's written approval of
the plans, specifications and working drawings for such Alterations, which
approval Landlord will not unreasonably withhold, condition or delay as long as
-10-
(i) Tenant delivers to Landlord notice and a copy of any final plans,
specifications and working drawings for any such Alterations at least ten (10)
days prior to commencement of the work thereof, and (ii) the other conditions of
this Section 12 are satisfied. Landlord shall approve or be deemed to have
approved all such requests for approval within twenty (20) days after request
therefor.
(c) CONTRACTORS. Alterations other than Permitted Alterations may be made or
installed only by contractors and subcontractors which have been approved by
Landlord, which approval Landlord will not unreasonably withhold, condition or
delay. Before proceeding with any Alterations, Tenant agrees to provide Landlord
with ten (10) days prior written notice and Tenant's contractors must obtain and
maintain, on behalf of Tenant and at Tenant's sole cost and expense all
necessary governmental permits and approvals for the commencement and completion
of such Alterations. Throughout the performance of any Alterations, Tenant
agrees to obtain, or cause its contractors to obtain, workers compensation
insurance and general liability insurance in compliance with the provisions of
Section 17 of this Lease.
(d) MANNER OF PERFORMANCE. All Alterations must be performed: (i) substantially
in accordance with the approved plans, specifications and working drawings (if
applicable); (ii) in a lien-free and first-class and workmanlike manner; and
(iii) in compliance with all applicable permits, laws, statutes, ordinances,
rules, regulations, orders and rulings now or hereafter in effect and imposed by
any governmental agencies and authorities having jurisdiction.
(e) OWNERSHIP. The Tenant Improvements and all Alterations will become the
property of Landlord and will remain upon and be surrendered with the Premises
and become the property of the Landlord at the end of the Term of this Lease;
provided, however, Landlord may, by written notice delivered to Tenant
concurrently with Landlord's approval of any Alterations, identify those
Alterations which Landlord will require Tenant to remove at the end of the Term
of this Lease. Tenant shall have no obligation to remove upon termination of the
Lease any initial Tenant Improvements constructed in accordance with the Work
Letter, any Alterations to which Landlord does not require removal in writing
concurrently with its approval of working drawings, or any Permitted
Alterations. If Landlord requires Tenant to remove any Alterations pursuant to
this Section, Tenant, at its sole cost and expense, agrees to remove the
identified Alterations on or before the expiration or earlier termination of
this Lease and repair any damage to the Premises caused by such removal and
return the Premises back to the substantially the same condition as when
originally received by Landlord, normal wear and tear and casualty excepted.
(f) PERSONAL PROPERTY. All articles of personal property owned by Tenant or
installed by Tenant at its expense in the Premises (including Tenant's business
and trade fixtures, furniture, movable partitions, raised floors, and equipment
such as telephones and switches, video conference equipment, projectors, copy
machines, computer terminals, wireless network equipment, refrigerators,
supplemental HVAC units and facsimile machines), whether or not attached to the
Building, will be and remain the property of Tenant, and must be removed by
Tenant from the Premises, at Tenant's sole cost and expense, on or before the
expiration or earlier termination of this Lease. Tenant agrees to repair any
damage caused by such removal at its cost on or before the expiration or earlier
termination of this Lease.
13. REPAIRS.
(a) LANDLORD'S OBLIGATIONS. Landlord agrees to repair and maintain or cause to
be repaired or maintained in a manner consistent with similar office buildings
with similar physical characteristics in King County and Snohomish County,
Washington, but in no event to a lesser standard than described in Exhibit "D"
attached hereto, the structural portions of the Building (including the shell
and core), the plumbing, heating, ventilating, air conditioning, elevator and
electrical systems for the Building, and all Exterior Areas (excluding the
Tenant Improvements, Alterations, and any improvements and equipment installed
by Tenant), unless such maintenance and repairs are caused by the act, neglect
or omission of any duty by Tenant or the Tenant Parties under this Lease.
Landlord will not be liable for any failure to make any such repairs or to
perform any maintenance unless such failure shall persist for ten (10) days (or
24 hours in the case of an emergency) after written notice of the need of such
repairs or maintenance is given to Landlord by Tenant.
-11-
(b) TENANT'S OBLIGATIONS. Subject to Landlord's repair and maintenance
obligations under Section 13(a) above and Exhibit "D" attached hereto, Tenant
agrees to keep, maintain and preserve the Premises in good condition and repair
(reasonable wear and tear, damage by casualty event, Landlord's repair and
maintenance obligations under this Lease and/or the negligence or misconduct of
Landlord or Landlord Parties excepted) and, when and if needed, at Tenant's sole
cost and expense, to make all repairs to the Premises and every part thereof.
Tenant has no authority to allow any liens to encumber all or any portion of the
Premises, and Tenant agrees to cause any mechanics' liens or other liens arising
as a result of work performed by Tenant or at Tenant's direction to be
eliminated as provided in Section 14 below.
(c) SELF-HELP. Notwithstanding anything to the contrary contained in this Lease,
Landlord agrees that if Landlord fails to perform any repair or maintenance
obligation under this Lease which it is obligated to perform within the time
periods set forth in Section 21 below, then Tenant shall be permitted to perform
such obligations on Landlord's behalf in the Premises, provided Tenant first
delivers to Landlord an additional three (3) business days' prior written notice
that Tenant will be performing such obligations, and provided further that
Landlord fails to commence to perform such obligations within such additional
three (3) business day period and diligently prosecute such work to completion.
Notwithstanding the foregoing, if the nature of the unperformed obligation is
such that a bona fide emergency involving an immediate and imminent danger to
life, health or property or material interference with Tenant's business exists,
the foregoing time periods and those set forth in Section 21 shall be reasonably
reduced based upon such emergency circumstances. All contractors engaged by
Tenant pursuant to this Section 13(c) shall be subject to Landlord's reasonable
approval, and Landlord agrees to approve or reject any contractor proposed to be
used by Tenant within twenty-four (24) hours of receipt of Tenant's second
notice, provided that if a proposed contractor is licensed and reputable, and
all requisite permits have been obtained for the desired work, then Landlord
shall be deemed to have given its approval of the proposed contractor. Any work
performed by Tenant, and the obligations of Landlord, pursuant to this Section
13(c) shall be subject to the terms of Section 21 below.
14. LIENS. Tenant has no authority to allow any liens to encumber all or any
portion of the Premises. Tenant agrees not to permit any mechanic's,
materialmen's or other liens to be filed against all or any part of the Land,
the Building or the Premises, nor against Tenant's leasehold interest in the
Premises, by reason of or in connection with any repairs, alterations,
improvements or other work contracted for or undertaken by Tenant or any other
act or omission of Tenant or the Tenant Parties. Landlord will have the right at
all reasonable times to post on the Premises and record any notices of
non-responsibility which it deems necessary for protection from such liens. If
any such liens are filed, Tenant will, at its sole cost, promptly cause such
liens to be released of record or removed by posting a bond in compliance with
RCW 60.04.161 so that they no longer affects title to the Land, the Building or
the Premises.
15. ENTRY BY LANDLORD. Landlord and its employees and agents will at all times
have the right to enter the Building as reasonably necessary to provide the
janitorial services pursuant to Exhibit "D" attached hereto (such service shall
be scheduled for outside of Normal Building Hours - "NORMAL BUILDING HOURS" for
the Building shall be 7:00 AM to 6:00 PM, Pacific Time, Monday through Friday;
and 8:00 AM to 1:00 PM Saturdays) and, upon at least forty-eight (48) hours'
prior written notice (except in cases of emergency) to Tenant, to (i) inspect
the Premises, perform maintenance, repairs and other obligations required to be
performed by Landlord under this Lease, (ii) show the Premises to prospective
purchasers and prospective lenders and/or, (iii) during the last nine (9) months
of the term only, show the Premises to prospective tenants. In exercising such
entry rights, Landlord will use commercially reasonable efforts to minimize, as
reasonably practicable, the interference with Tenant's business, and will
provide Tenant with reasonable advance notice of any such entry (except in
emergency situations). Landlord, in exercising its rights under this Lease, (i)
shall not interfere with access to the Premises or Tenant's use and enjoyment of
the Premises, the Parking Areas and/or the Exterior Areas, (ii) shall in no
event have access to Tenant's designated secure area except in the case of an
emergency, and (iii) shall repair, restore and redecorate any damage to the
Premises caused by or at the direction of Landlord in exercising such rights.
Prior notice is not required for Landlord to inspect the Premises outside the
Building.
-12-
16. UTILITIES AND SERVICES. Throughout the Term of the Lease so long as the
Premises are occupied, Tenant, at its sole cost and expense, shall be
responsible for obtaining directly from the utility providers all utilities to
the Premises, including but not limited to electricity, sewer, water, natural
gas, telephone, and cable (collectively the "UTILITIES"). Landlord (as an
Operating Expense) agrees to furnish or cause to be furnished only those
utilities and services described in the Standards for Services attached hereto
as Exhibit "D", subject to the conditions and in accordance with the standards
set forth therein.
17. INSURANCE.
(a) TENANT'S INSURANCE. On or before the earlier to occur of (i) the
Commencement Date, or (ii) the date Tenant commences any work of any type in the
Premises pursuant to this Lease (which may be prior to the Commencement Date),
and continuing throughout the entire Term hereof and any other period of
occupancy, Tenant agrees to keep in full force and effect, at its sole cost and
expense, the following insurance:
(i) "Causes of Loss - Special Form" (or, if not available at any time,
then the broadest form available at such time) property insurance including at
least the following perils: fire and extended coverage, smoke damage, vandalism,
malicious mischief, sprinkler leakage. This insurance policy must be upon all
property owned by Tenant and located at the Building including, without
limitation, any Alterations made by or for the Tenant (expressly excluding the
initial Tenant Improvements installed by Tenant per Exhibit "B" which shall be
insured by Landlord as part of its coverage of the Building's shell and core),
and all furniture, fittings, installations, fixtures and any other personal
property of Tenant, in an amount not less than the full replacement cost
thereof.
(ii) Commercial General Liability Insurance or Comprehensive General
Liability Insurance with an aggregate liability amount not less than $5,000,000
combined single limit for both bodily injury and property damage, including
blanket broad form property damage, personal injury, completed operations,
products liability and host liquor liability (or liquor liability, if
applicable). At least $1,000,000 of such coverage shall be provided by a primary
liability policy, and any balance may be provided by a so-called "umbrella" or
excess liability policy. If such policy is an aggregate liability limit policy,
not less than $5,000,000 of such limit per annum shall be available for claims
originating at the Premises.
(iii) Workers' Compensation as required by the laws of the State,
including employer's liability at a limit of not less than One Million Dollars
($1,000,000).
(b) SUPPLEMENTAL TENANT INSURANCE REQUIREMENTS.
(i) All policies must be issued by insurers with a policyholder rating of
"A" and a financial rating of "VIII" in the most recent version of Best's Key
Rating Guide.
(ii) All policies, except for the workers' compensation coverage required
pursuant to Section 17(a)(iii) above, must contain a requirement that the
insurer will endeavor to notify Landlord (and Landlord's partners, members and
property manager and any mortgagees or ground lessors of Landlord who are named
as additional insureds, if any) in writing not less than ten (10) days prior to
any material adverse change, reduction in coverage, cancellation or other
termination thereof. Tenant agrees to deliver to Landlord, as soon as
practicable after placing the required insurance, but in any event within the
time frame specified in Section 17(a) above, certificate(s) of insurance
evidencing the existence of such insurance (except for the workers' compensation
coverage required pursuant to Section 17(a)(iii) above) and Tenant's compliance
with the provisions of this Section 17. Tenant agrees to cause replacement
certificates to be delivered to Landlord not less than ten (10) days prior to
the expiration of any such policy or policies.
(iii) General Liability policies under Section 17(a)(ii) must include
policy endorsements naming Landlord (and at Landlord's request, Superior
Mortgagees of which Tenant has been informed in writing) as additional insureds.
-13-
(c) MUTUAL WAIVER OF PARTIES. Landlord and Tenant hereby waive their rights
against each other with respect to any claims or damages or losses which are
caused by or result from (a) any occurrence insured against under any insurance
policy (other than the commercial general liability insurance) carried by
Landlord or Tenant (as the case may be) pursuant to the provisions of this Lease
and enforceable at the time of such damage or loss, or (b) any occurrence which
would have been covered under any insurance (other than the commercial general
liability insurance) required to be obtained and maintained by Landlord or
Tenant (as the case may be) under this Lease (as applicable) had such insurance
been obtained and maintained as required therein. The foregoing waivers shall be
in addition to, and not a limitation of, any other waivers or releases contained
in this Lease.
(d) WAIVER OF INSURERS. Each party shall cause each insurance policy (other than
the commercial general liability insurance) required to be obtained by it
pursuant to this Lease to provide that the insurer waives all rights of recovery
by way of subrogation against either Landlord or Tenant, as the case may be, in
connection with any claims, losses and damages covered by such policy. If either
party fails to maintain any such insurance required hereunder, such insurance
shall be deemed to be self-insured with a deemed full waiver of subrogation as
set forth in the immediately preceding sentence.
(e) LANDLORD INSURANCE.
(i) "LANDLORD INSURANCE" shall mean the following: (a) Commercial General
Liability Insurance, including Contractual Liability Insurance coverage,
applicable to the Building and Land, on an occurrence basis, with a minimum
combined single limit of at least $5,000,000; (b) property insurance on the
Building (including Tenant Improvements) and Land (including parking), and
personal property related thereto, with coverage for perils as set forth under
the Causes of Loss - Special Form (or, if not available at any time, then the
broadest form available at such time), with coverage extended for the perils of
flood and earthquake, in an amount equal to full insurable replacement cost, and
with an ordinance and law endorsement, and debris removal coverage; (c) Rent
Loss Insurance for not less than twelve (12) months, and not more than
twenty-four (24) months; and (d) such other coverage as may be required by
Landlord's lender holding a lien against the Building and Land provided that
such insurance coverage is commercially reasonable given the location and
physical characteristics of the Building.
(ii) If at any time Landlord does not maintain any one or more of the
policies of Landlord Insurance as provided in this Section 17(e), then Tenant
may obtain the policy or policies that are not maintained by Landlord (the
"NON-MAINTAINED POLICY"), at Tenant's expense (including the payment of any
deductibles). If Tenant maintains an insurance policy in replacement of a
Non-maintained Policy, and Landlord subsequently decides to obtain a policy with
such coverage, then Landlord may not charge to Tenant, as an Operating Expense,
the cost of the policy until after thirty (30) days' prior written to Tenant. If
at any time Landlord maintains insurance not included in the definition of
Landlord Insurance, Landlord may not charge to Tenant as an Operating Expense,
the additional cost of such coverage.
(f) BLANKET INSURANCE. Notwithstanding anything to the contrary in this Section
17, Tenant's obligation to obtain and maintain the insurance required hereunder
may be satisfied by obtaining coverage under so-called blanket and excess
liability policies of insurance carried and maintained by Tenant provided that
the coverage afforded Landlord will not be reduced or diminished by reason of
the use of such blanket and excess liability policies of insurance and provided
further that the other applicable requirements of this Section 17 are satisfied.
18. DAMAGE OR DESTRUCTION.
(a) PARTIAL DESTRUCTION. If the Premises, the Building or the Exterior Areas
(including Parking Areas) are damaged by fire or other casualty to an extent not
exceeding fifty percent (50%) of the full replacement cost thereof, and the
damage thereto may be repaired, reconstructed or restored to substantially its
condition immediately prior to such damage within three hundred sixty five (365)
days from the date of such casualty, then Landlord agrees to commence and
proceed diligently with the work of repair, reconstruction and restoration and
this Lease will continue in full force and effect. Landlord agrees to give
written notice to Tenant of its intention to repair or terminate, as permitted
above, within
-14-
the earlier of sixty (60) days after the occurrence of such casualty, or fifteen
(15) days after Landlord's receipt of the estimate from Landlord's contractor
(the applicable time period to be referred to herein as the "Notice Period").
(b) SUBSTANTIAL DESTRUCTION. Any damage or destruction to the Premises, the
Building or the Exterior Areas (including the Parking Areas) which Landlord is
not obligated to repair pursuant to Section 18(a) above will be deemed a
substantial destruction. In the event of a substantial destruction, either
Landlord or Tenant may elect to terminate this Lease effective as of the date
thirty (30) days after receipt of either party's written election to so
terminate; provided, however, that such written notice to so terminate shall be
effective only if given within sixty (60) days after the occurrence of such
casualty. If this Lease is not terminated in accordance with this Section 18(b),
then Landlord shall repair, reconstruct and restore the portion of the Building,
the Premises and the Exterior Areas damaged by such casualty in accordance with
this Section 18.
(c) RESTORATION OBLIGATIONS. In the event of any damage or destruction of all or
any part of the Premises, Tenant agrees to immediately notify Landlord thereof.
Landlord shall insure the Tenant Improvements installed by Tenant pursuant to
Exhibit "B" and, subject to any termination rights hereunder, shall be
responsible for repairing and restoring the Tenant Improvements if Landlord
elects or is required to repair and restore the Premises, the Building and/or
the Exterior Areas under this Lease. Subject to Section 12, at Tenant's expense
as provided in this Lease, Tenant shall restore any Alterations and Tenant's
furniture, fixtures, equipment and other personal property unless this Lease is
terminated as permitted in this Section 18.
(d) ABATEMENT OF RENT. In the event of any damage, repair, reconstruction and/or
restoration described in this Section 18, rent will be abated or reduced, as the
case may be, from the date of such casualty, in proportion to the degree to
which Tenant's use of the Building is impaired during such period of repair
until Landlord completes all repairs to be performed by Landlord under this
Lease and Tenant has been given a reasonable period of time not to exceed
forty-five (45) days to re-fixturize and move back into the Premises.
(e) INABILITY TO COMPLETE. Notwithstanding anything to the contrary contained in
this Section 18, if Landlord is obligated or elects to repair, reconstruct
and/or restore the damaged portion of the Building or the Premises pursuant to
Section 18(a) or 18(b) above, but is delayed from completing such repair,
reconstruction and/or restoration beyond the date which is the earlier of (i)
forty-five (45) days after the date estimated by Landlord's contractor for
completion thereof by reason of any causes (other than delays caused by Tenant
or Tenant Parties, but excluding Force Majeure Delay pursuant to Section 27
below) or (ii) three hundred sixty five (365) days after the date of the
casualty damage, then Tenant may elect to terminate this Lease upon ten (10)
days' prior written notice given to Landlord after the expiration of such
forty-five (45) day period (unless the work is completed within such ten (10)
day notice period.
(f) DAMAGE NEAR END OF TERM. Either Landlord or Tenant shall have the right to
terminate this Lease if any damage to the Building occurs during the last twelve
(12) months of the Term of this Lease and either Landlord or Tenant reasonable
determines that the restoration of such damage cannot be completed within sixty
(60) days after the date of such casualty; provided, however, notwithstanding
any provision of this Lease to the contrary, if Landlord has elected to
terminate this Lease pursuant to this Section 18(f), then within thirty (30)
days after receipt of written notice of such termination, Tenant may exercise
any of its unexercised Extension Options, which exercise shall negate and render
null and void Landlord's election to terminate this Lease, and the restoration
of the Building and other improvements to the Land shall proceed in accordance
with this Section 18.
(g) TERMINATION. Upon any termination of this Lease under any of the provisions
of this Section 18, the Parties will be released without further obligation to
the other from the date possession of the Premises is surrendered to Landlord
except for items which have accrued and are unpaid as of the date of termination
and matters which are to survive any termination of this Lease as provided in
this Lease.
-15-
(h) SUBORDINATION. Nothing in this Section 18 shall be construed as overriding
any requirements in the Superior Mortgages regarding damage and/or destruction,
and the Landlord's obligations in connection therewith, and/or any provisions or
requirements in the Superior Mortgages regarding the use and control of
insurance proceeds; all provisions in this Section 18 shall be subject and
subordinate to the requirements and provisions of the Superior Mortgages;
provided, however, Landlord and Tenant acknowledge and agree that this Section
18(h) shall not operate to absolve or otherwise excuse Landlord from Landlord's
obligation to restore the Premises when and as required pursuant to this Section
18.
19. EMINENT DOMAIN.
(a) SUBSTANTIAL TAKING. If the whole of the Building, or such part of the Land
or the Building as shall substantially and adversely interfere with Tenant's use
and occupancy of the Premises as contemplated by this Lease (including without
limitation Tenant's use of the Parking Areas), is taken for any public or
quasi-public purpose by any lawful power or authority by exercise of the right
of appropriation, condemnation or eminent domain, or sold to prevent such
taking, then Tenant will have the right to terminate this Lease effective as of
the date possession is required to be surrendered to such authority. With
respect to a taking or condemnation affecting solely the number of parking
spaces available in the Parking Areas, so long as the number of parking stalls
remaining on the Land are not reduced below the minimum number required by City
of Bothell codes applicable to Tenant's use of the Premises, then such taking
shall not be deemed to substantially and/or adversely interfere with Tenant's
use and occupancy of the Premises provided that reasonable ingress and egress to
the Parking Areas from public streets remains available.
(b) PARTIAL TAKING; ABATEMENT OF RENT. In the event of a taking of a portion of
the Building which does not materially or adversely interfere with Tenant's use
and occupancy of the Building, then Landlord will thereafter proceed to make a
functional unit of the remaining portion of the Building, and rent will be
abated with respect to the part of the Building which Tenant is deprived of on
account of such taking.
(c) CONDEMNATION AWARD. In connection with any taking of the Premises or the
Building, Landlord will be entitled to receive the entire amount of any award
which may be made or given in such taking or condemnation, without deduction or
apportionment for any estate or interest of Tenant, it being expressly
understood and agreed by Tenant that no portion of any such award will be
allowed or paid to Tenant for any so-called bonus or excess value of this Lease,
and such bonus or excess value will be the sole property of Landlord. Tenant
agrees not to assert any claim against Landlord or the taking authority for any
compensation because of such taking (including any claim for bonus or excess
value of this Lease); provided, however, if any portion of the Premises is
taken, Tenant will have the right to recover from the condemning authority (but
not from Landlord) any compensation as may be separately awarded or recoverable
by Tenant for the taking of Tenant's furniture, fixtures, equipment and other
personal property within the Premises (but not the Tenant Improvements), for
Tenant's relocation expenses, for any loss of goodwill or other damage to
Tenant's business by reason of such taking, and any other damages that may be
recovered under the laws of the State, so long as any award to Tenant does not
reduce any award to Landlord.
(d) TEMPORARY TAKING. In the event of taking of the Building or any part thereof
for temporary use, (i) this Lease will remain unaffected thereby and rent will
xxxxx for the duration of the taking in proportion to the extent Tenant's use of
the Building is interfered with, and (ii) Landlord will be entitled to receive
such portion or portions of any award made for such use. For purpose of this
Section 19(d), a temporary taking shall be defined as a taking for a period of
ninety (90) days or less.
20. DEFAULTS AND REMEDIES.
(a) DEFAULTS. The occurrence of any one or more of the following events will be
deemed a "Default" by Tenant:
(i) The failure by Tenant to make any payment of Rent or any other payment
required to be made by Tenant hereunder, as and when due, where such failure
continues for a period of five (5) business days
-16-
after written notice thereof from Landlord to Tenant; provided, however, that
written notice shall not be required more than twice in any calendar year.
(ii) The failure by Tenant to observe or perform any of the express or implied
covenants or provisions of this Lease to be observed or performed by Tenant,
other than as specified in Section 20(a)(i) above, where such failure continues
(where no other period of time is expressly provided) for a period of thirty
(30) days after written notice thereof from Landlord to Tenant. If the nature of
Tenant's Default is such that more than thirty (30) days are reasonably required
for its cure, then Tenant will not be deemed to be in Default if Tenant
commences such cure within such thirty (30) day period and thereafter diligently
prosecutes such cure to completion, but in not event longer than one hundred
twenty (120) days.
(iii) (a) The making by Tenant of any general assignment for the benefit of
creditors; (b) the filing by or against Tenant of a petition to have Tenant
adjudged a bankrupt or a petition for reorganization or arrangement under any
law relating to bankruptcy (unless, in the case of a petition filed against
Tenant, the same is dismissed within sixty (60) days); (c) the appointment of a
trustee or receiver to take possession of substantially all of Tenant's assets
located at the Premises or of Tenant's interest in this Lease, where possession
is not restored to Tenant within sixty (60) days; or (d) the attachment,
execution or other judicial seizure of substantially all of Tenant's assets
located at the Premises or of Tenant's interest in this Lease where such seizure
is not discharged within sixty (60) days.
(b) LANDLORD'S REMEDIES. After the occurrence of a Default by Tenant, Landlord
may, at its option, immediately declare Tenant's rights under this Lease
terminated, and, subject to the requirements of applicable laws, reenter the
Premises using such force as may be necessary, and repossess itself thereof, as
of its former estate, and remove all persons and property from the Premises.
Notwithstanding any such reentry, the liability of Tenant for the full Rent
provided for herein shall not be extinguished for the balance of this Lease, and
Tenant shall make good to Landlord any deficiency arising from a reletting of
the Premises at a lesser Rent, plus the costs and expenses of renovating,
altering and reletting the Premises, including attorneys' fees or brokers' fees
incident to Landlord's reentry or reletting. Tenant shall pay any such
deficiency each month as the amount thereof is ascertained by Landlord or, at
Landlord's option, Landlord may recover in addition to all Rent and any other
sums unpaid at the time of judgment, the present value of the amount at the time
of judgment by which the unpaid Rent for the balance of the Lease Term after
judgment exceeds the amount of Rent loss which Tenant proves could be reasonably
avoided, discounted at the rate of five percent (5%). In reletting the Premises,
Landlord may grant commercially reasonable rent concessions and the amount due
from Tenant shall not be reduced thereby. Nothing herein shall be deemed to
affect the right of Landlord to recover for indemnification under any provision
herein, for matters which occurred prior to the termination of this Lease, or
for any other remedy at law or in equity. Tenant acknowledges that if Tenant is
in Default under this Lease and at that time any other property owned by
Landlord is available for lease, Landlord has the right to lease such other
premises, and this shall not reduce Tenant's obligations under this Lease
through the remaining Lease Term.
(c) LANDLORD'S REMEDIES; PERFORMANCE FOR TENANT. All covenants and agreements to
be performed by Tenant under any of the terms of this Lease are to be performed
by Tenant at Tenant's sole cost and expense and, except as expressly provided in
this Lease, without any abatement of Rent. If Tenant fails to pay any sum of
money owed to any party other than Landlord, for which it is liable under this
Lease, or if Tenant fails to perform any other act on its part to be performed
hereunder, and such failure constitutes a Default by Tenant, Landlord may,
without waiving or releasing Tenant from its obligations, but shall not be
obligated to, make any such payment or perform any such other act to be made or
performed by Tenant. Tenant agrees to reimburse Landlord upon demand for all
sums so paid by Landlord and all necessary incidental costs, together with
interest thereon at the Interest Rate, from the date of such payment by Landlord
until reimbursed by Tenant. This remedy shall be in addition to any other right
or remedy of Landlord set forth in this Section 20.
(d) LATE PAYMENT. If Tenant fails to pay any installment of Rent within ten (10)
days of when due or if Tenant fails to make any other payment for which Tenant
is obligated under this Lease within ten (10)
-17-
days of when due, such late amount will accrue interest at the Interest Rate and
Tenant agrees to pay Landlord as additional rent such interest on such amount
from the date such amount becomes due until such amount is paid. In addition,
Tenant agrees to pay to Landlord concurrently with such late payment amount, as
additional rent, a late charge equal to five percent (5%) of the amount due to
compensate Landlord for the extra costs Landlord will incur as a result of such
late payment. Acceptance of any such interest and late charge will not
constitute a waiver of the Tenant's Default with respect to the overdue amount,
or prevent Landlord from exercising any of the other rights and remedies
available to Landlord. Notwithstanding the foregoing, for the first two (2)
monetary delinquencies in any calendar year, Tenant shall be entitled to receive
written notice and five (5) business days from receipt of such notice to cure
such monetary delinquency before Landlord may assess any interest or late
charges under this Lease.
(e) RIGHTS AND REMEDIES CUMULATIVE. All rights, options and remedies of Landlord
and Tenant contained in this Lease will be construed and held to be cumulative,
and no one of them will be exclusive of the other, and except as otherwise
expressly stated in this Lease, Landlord and Tenant shall have the right to
pursue any one or all of such remedies or any other remedy or relief which may
be provided by law or in equity, whether or not stated in this Lease. Nothing in
this Section 20 will be deemed to limit or otherwise affect each party's
indemnification of the other pursuant to any provision of this Lease.
21. LANDLORD'S DEFAULT. Landlord's failure to perform or observe any of its
obligations under this Lease or to correct a breach of any warranty or
representation made in this Lease (provided that such breach of representation
or warranty is reasonably susceptible of cure) within thirty (30) days after
receipt of written notice from Tenant setting forth in reasonable detail the
nature and extent of the failure referencing pertinent Lease provisions or if
more than thirty (30) days is required to cure the breach, Landlord's failure to
begin curing within the thirty (30) day period and diligently prosecute the cure
to completion, shall constitute a default. If Tenant has provided simultaneous
written notice thereof to Superior Mortgagees (if any and if Tenant has notice
thereof) and Landlord (and/or Superior Mortgagees if any) has failed to commence
to cure such default within thirty (30) days (or such shorter time as is
commercially reasonable in the case of an emergency threatening imminent harm to
persons or property), Tenant may at its option (but shall not be obligated),
without waiving any claim for breach of agreement, thereafter cure the default
for the account of the Landlord, which cure shall be preceded by an additional
written notice given at least three (3) days prior to such cure to Landlord and
Superior Mortgagees that Tenant plans to undertake the cure, and the reasonable
cost of such cure shall be deemed paid or incurred for the account of Landlord,
and Landlord shall reimburse Tenant for Tenant's out-of-pocket expenditures paid
to third parties to effectuate such cure, such reimbursement to be within thirty
(30) days after completion of the cure and invoice to Landlord showing the costs
of cure. If Tenant elects to exercise such cure rights, such election shall be
in lieu of any right to terminate this Lease for purposes of such cured default
only; Tenant shall not have the right to terminate this Lease for any Landlord
default which Tenant has elected to cure as provided in this Section 21. If
Landlord disputes either the necessity of the cure or the cost thereof, the
matter shall be settled by arbitration in Seattle, Washington, pursuant to
Section 33(n) below. The arbitration shall be held within sixty (60) days of
Landlord notifying Tenant it disputes Tenant's cure. If Landlord fails to
reimburse Tenant within the 30 day period above (or, if disputed then within ten
(10) days after final determination in the arbitration), then thereafter Tenant
may offset such reimbursement against the monthly Rent (but not additional rent)
up to a maximum of a 25% offset in any month, until Tenant has recovered the
entire expenditure.
22. ASSIGNMENT AND SUBLETTING.
(a) RESTRICTION ON TRANSFER. Tenant shall have not have the right to assign,
encumber, sublease, or transfer this Lease without Landlord's prior written
consent, which shall be unreasonably withheld or delayed (any such assignment,
encumbrance, sublease, or transfer will sometimes be referred to as a
"Transfer"). Upon a Transfer, or a request therefor, Landlord shall not have the
right to recapture the Premises. Any Transfer shall state that the Transferee
shall make all payments under the assignment or sublease directly to Landlord,
after written notice from Landlord of an uncured Default by Tenant under this
Lease. Tenant agrees that all payments from Transferee shall be payable directly
to Landlord for the duration of any uncured Default by Tenant under this Lease.
-18-
(b) NON-TRANSFERS. Notwithstanding the provisions of this Section 22 to the
contrary, for purposes of this Section 22, a reorganization, merger, sale,
partnership change, assignment, transfer or hypothecation of any partnership or
other ownership interest in Tenant shall not be deemed a Transfer under the
Lease so long as the successor entity reasonably has the financial wherewithal
to perform its obligations under this Lease. If the successor entity has
comparable or greater financial strength to that of the Tenant as of the
Commencement Date, then such successor entity shall be conclusively deemed to
have the financial wherewithal to perform its obligations under the Lease. The
use by or the subletting of all or a portion of the Premises to any subsidiary
or Affiliate of Tenant shall not constitute a Transfer under this Lease or
require the prior written consent of Landlord. Tenant may allow any person or
company which is a client or customer of Tenant, or which is providing a service
to Tenant or one of Tenant's clients, to occupy certain portions of the Building
without such occupancy being deemed a Transfer. For purposes of this Lease, an
"Affiliate" of any entity shall mean another entity which controls, is
controlled by, or is under common control with such entity. Prior to effecting a
sublease, assignment or other transfer pursuant to this Section 22(b), Tenant
shall provide to Landlord reasonable evidence that such transaction satisfies
the requirements of this Section 22(b). If confidentiality obligations or the
requirements of securities or other laws preclude the disclosure of such
transaction prior to its closing, then Tenant shall provide such evidence to
Landlord within ten (10) business days after the closing of such transaction.
(c) TRANSFER NOTICE. If Tenant desires to effect a Transfer, then at least ten
(10) days prior to the date when Tenant desires the Transfer to be effective
(the "Transfer Date"), Tenant agrees to give Landlord a written notice (the
"Transfer Notice"), stating the name, address and business of the proposed
assignee, sublessee, encumbrance holder, or other transferee (sometimes referred
to hereinafter as "Transferee"), reasonable information (including references)
concerning the ownership, and financial condition of the proposed Transferee,
the Transfer Date, any ownership or commercial relationship between Tenant and
the proposed Transferee, and the consideration and all other material terms and
conditions of the proposed Transfer, all in such detail as Landlord may
reasonably require. Within ten (10) days of Landlord's receipt of any Transfer
Notice (including all the information described above), and Landlord will elect
in writing to do one of the following (i) consent to the proposed Transfer; or
(ii) refuse such consent, which refusal shall be on reasonable grounds (set
forth in reasonable detail in such notice of election).
(d) EXCESS RENT. In the event of any Transfer, Tenant shall pay to Landlord, as
additional rent, fifty percent (50%) of all sums and other consideration payable
to and for the benefit of Tenant by the Transferee assignee on account of the
Transfer, after recovery of Tenant's Re-Leasing Costs (as defined below), as and
when such sums and other consideration are due and payable by the Transferee
(or, if Landlord so requires, and without any release of Tenant's liability for
the same, Tenant agrees to instruct the Transferee to pay such sums and other
consideration directly to Landlord). If for any proposed sublease Tenant
receives Rent or other consideration, either initially or over the term of the
sublease, in excess of the Rent fairly allocable to the portion of the Building
which is subleased based on rentable square footage, Tenant agrees to pay to
Landlord as additional rent fifty percent (50%) of the excess of each such
payment of Rent or other consideration received by Tenant, after recovery of
Tenant's Re-Leasing Costs (as defined below), within ten (10) days after its
receipt. In calculating excess Rent or other consideration which may be payable
to Landlord under this subsection, Tenant will be entitled to deduct
commercially reasonable third party brokerage commissions, transaction costs,
tenant improvement costs or allowances funded by Tenant, tenant incentives,
rental abatement or free rent awarded or granted to the Transferee, attorneys'
fees and other amounts reasonably and actually paid by Tenant to third parties
in connection with such assignment or subletting ("Tenant's Re-Leasing Costs")
if acceptable written evidence of such expenditures is provided to Landlord.
(e) MISCELLANEOUS. Any Transferee of Tenant shall deliver to Landlord a true
copy of the fully executed instrument of assignment, sublease, transfer or
hypothecation, and, in the case of an assignment, the delivery to Landlord of an
agreement executed by the Transferee in form and substance reasonably
satisfactory to Landlord, whereby the Transferee assumes and agrees to be bound
by all of the terms and provisions of this Lease and to perform all of the
obligations of Tenant hereunder.
-19-
(f) NO RELEASE. No Transfer (or non-transfer permitted pursuant to Section 22(b)
above), whether or not permitted, nor Landlord's consent thereto, shall operate
to release Tenant from liability under this Lease. Tenant shall remain jointly
and severally liable under this Lease, along with any Transferee.
Notwithstanding the foregoing, Emulex Design & Manufacturing Corporation, as the
assigning Tenant, and Emulex Corporation, as the guarantor of this Lease, shall
be released from any further obligations and/or liability which first arise
under this Lease from and after the effective date of any assignment of the
Lease to a Transferee if all of the following are met in connection with such
assignment:
(i) The Transferee has a net worth at the time of such assignment of at
least Three Hundred Million Dollars ($300,000,000) as determined in
accordance with generally accepted accounting principles.
(ii) The Transferee executes and delivers to Landlord an assumption of
this Lease in accordance with Section 22(e) above.
(g) COSTS. If Tenant requests Landlord's consent to any Transfer, Tenant shall
reimburse Landlord for its reasonable out-of-pocket legal and out-of-pocket
administrative costs incurred in connection with such request.
(h) LANDLORD COOPERATION. The Landlord agrees to reasonable cooperate with the
Tenant in making arrangements for a Transferee in accordance with this Section
22. Should Tenant make a written request to Landlord requesting Landlord to
offer an assignment of this Lease on the open market, Landlord shall do so by
listing the Premises with a broker or brokers and using reasonable efforts to
engage a Transferee, and Tenant shall pay to the Landlord an amount equal to one
hundred twenty percent (120%) of the sum of the commission to such broker and
the actual reasonable expenses of the Landlord, provided, however, that
Landlord's reimbursable expenses (other than commissions due) shall not exceed
twenty-five thousand dollars ($25,000). Should an assignment of this Lease not
be executed by an assignee within one hundred eighty (180) days of such a
request by Tenant, then Tenant shall have the option to require the Landlord to
discontinue the listing of the Premises, and to discontinue efforts by the
Landlord to engage a Transferee, and the obligations of Tenant for such efforts
shall be limited to paying the actual reasonable expenses of the Landlord
therefore in a total payment amount not to exceed any payment due to real estate
brokers, plus twenty-five thousand dollars ($25,000).
23. SUBORDINATION.
(a) CURRENT LIENHOLDERS. No later than thirty (30) days after the Effective
Date, Landlord shall provide Tenant with a Subordination, Non-Disturbance and
Attornment Agreement ("SNDA") substantially in the form attached hereto as
Exhibit "E", or on another commercially reasonable form required by the Superior
Mortgagee, from any mortgage holders or lien holders (each, a "SUPERIOR
MORTGAGEE") then in existence. (A "SUPERIOR MORTGAGE" shall mean a lien
encumbering the Premises held by a Superior Mortgagee, and any documents
evidencing the debt secured by such lien.) Any SNDAs executed pursuant to this
Section 22 shall subordinate this Lease to the Superior Mortgage and include the
Superior Mortgagee's agreement to not disturb Tenant for so long as Tenant has
not committed a Default under this Lease.
(b) FUTURE LIENS. Tenant agrees to subordinate this Lease and its interest in
the Premises and the Land to the lien of any Superior Mortgagee who comes into
existence at any time prior to the expiration of the Term, provided that such
subordination is conditioned upon the Superior Mortgagee's delivery to Tenant of
an executed SNDA substantially in the form of Exhibit "E", or on another
commercially reasonable form required by the Superior Mortgagee.
(c) ATTORNMENT. Subject to the provisions of this Section, in the event of any
foreclosure of any or all mortgages or deeds of trust encumbering the Premises
by trustee's sale, voluntary agreement, deed in lieu of foreclosure, or by the
commencement of any judicial action seeking foreclosure, Tenant, at the request
of the then landlord under this Lease, shall attorn to and recognize the
beneficiary or purchaser at the foreclosure sale, as Tenant's landlord under
this Lease, and Tenant agrees to execute and deliver at
-20-
any time upon request of such ground or underlying lessor, beneficiary,
purchaser, or their successors, any commercially reasonable instrument
evidencing such attornment that does not amend Tenant's rights under this Lease.
24. ESTOPPEL CERTIFICATE.
(a) TENANT'S OBLIGATIONS. Within ten (10) business days following any written
request which Landlord may make from time to time, Tenant agrees to execute and
deliver to Landlord a statement, in a form substantially similar to the form of
Exhibit "F-1" attached hereto or as may reasonably be required by a Superior
Mortgagee, certifying to Tenant's actual knowledge (subject to any applicable
exceptions set forth in such statement): (i) the Commencement Date of this
Lease; (ii) the fact that this Lease is unmodified and in full force and effect
(or, if there have been modifications, that this Lease is in full force and
effect, and stating the date and nature of such modifications); (iii) the date
to which the rent and other sums payable under this Lease have been paid; (iv)
that, to the best of Tenant's knowledge, there are no current Defaults under
this Lease by either Landlord except as specified in Tenant's statement; and (v)
such other matters reasonably requested by Landlord. Landlord and Tenant intend
that any statement delivered pursuant to this Section 24 may be relied upon by
any mortgagee, beneficiary, purchaser or prospective purchaser of the Building
or any interest therein.
(b) TENANT'S FAILURE TO DELIVER. Tenant's failure to deliver such statement
within such time will be conclusive upon Tenant (i) that the statement as
submitted is correct without modification, and this Lease is in full force and
effect, without modification except as may be represented by Landlord, (ii) that
there are no uncured Defaults in Landlord's performance, and (iii) that not more
than one (1) month's rent has been paid in advance. Without limiting the
foregoing, if Tenant fails to deliver any such statement within such ten (10)
business day period, Landlord may deliver to Tenant an additional request for
such statement and Tenant's failure to deliver such statement to Landlord within
five (5) business days after delivery of such additional request will constitute
a Default under this Lease.
(c) LANDLORD'S OBLIGATIONS. No more than once per calendar year (unless
requested in connection with an assignment, sublease or other transfer of
Tenant's interest in the Lease), within ten (10) business days following any
written request from Tenant, Landlord agrees to execute and deliver to Tenant a
statement, in a form substantially similar to the form of Exhibit "F-2" attached
hereto, certifying to Landlord's actual knowledge (subject to any applicable
exceptions set forth in such statement): (i) the Commencement Date of this
Lease; (ii) the fact that this Lease is unmodified and in full force and effect
(or, if there have been modifications, that this Lease is in full force and
effect, and stating the date and nature of such modifications); (iii) the date
to which the rent and other sums payable under this Lease have been paid; (iv)
whether Landlord has delivered to Tenant a notice of default which has not been
fully cured by Tenant; and (v) whether, in Landlord's actual knowledge, without
inquiry or investigation, there exists any event or condition which with the
giving of notice or the passage of time would constitute a Default by Tenant
under this Lease. Landlord and Tenant intend that any statement delivered
pursuant to this Section 24(c) may be relied upon by any prospective Transferee,
lender, purchaser and/or investor of any interest in Tenant or its interest
under this Lease.
(d) LANDLORD'S FAILURE TO DELIVER. If Landlord fails to deliver any such
statement within such ten (10) business day period, Tenant may deliver to
Landlord an additional request for such statement and Landlord's failure to
deliver such statement to Tenant within five (5) business days after delivery of
such additional request will (A) be conclusive upon Landlord (i) that this Lease
is in full force and effect, (ii) that not more than one (1) month's rent has
been paid in advance; (iii) that there are no uncured defaults that have been
the subject of a written notice by Landlord; and (iv) that Landlord has no
actual knowledge of any event or condition which with the giving of notice or
the passage of time would constitute a Default by Tenant under this Lease; and
(B) cause Landlord to be liable for and Landlord shall pay to Tenant upon demand
Five Hundred Dollars ($500.00) per day for each day beyond the expiration of the
foregoing second five (5) business day period that Landlord delays in delivering
the statement to Tenant.
-21-
25. WAIVER. The waiver by either party of any breach of any term, covenant or
condition herein contained will not be deemed to be a waiver of any subsequent
breach of the same or any other term, covenant or condition herein contained.
The subsequent acceptance of Rent or any other payment hereunder by Landlord
will not be deemed to be a waiver of any preceding breach by Tenant of any term,
covenant or condition of this Lease, other than the failure of Tenant to pay
only that portion of the Rent so accepted, regardless of Landlord's knowledge of
such preceding breach at the time of acceptance of such Rent. No acceptance by
Landlord of a lesser sum than the Monthly Base Rent and additional rent or other
sum then due will be deemed to be other than on account of the earliest
installment of such Rent or other amount due, nor will any endorsement or
statement on any check or any letter accompanying any check be deemed an accord
and satisfaction, and Landlord may accept such check or payment without
prejudice to Landlord's right to recover the balance of such installment or
other amount or pursue any other remedy provided in this Lease. The consent or
approval of Landlord to or of any act by Tenant requiring Landlord's consent or
approval will not be deemed to waive or render unnecessary Landlord's consent or
approval to or of any subsequent similar acts by Tenant.
26. PARKING. So long as this Lease is in effect, Landlord grants to Tenant and
its employees, agents, customers, visitors, officers, contractors, licensees and
invitees the exclusive right to use all parking spaces located on the Land.
Landlord shall not reduce the number of parking stalls on the Land below the
amount present on the Effective Date.
27. FORCE MAJEURE. If either Landlord or Tenant is delayed, hindered in or
prevented from the performance of any act required under this Lease by reason of
an unusual and unforeseeable event (each a "Force Majeure Event") not within the
reasonable control of the party delayed in performing work or doing acts
required under the provisions of this Lease, then performance of such act will
be excused for the period of the delay and the period for the performance of any
such act will be extended for a period equivalent to the period of such delay (a
or "Force Majeure Delay"). Force Majeure Events include, but are not limited to,
strikes, lock-outs, labor troubles, inability to procure standard materials,
restrictive governmental laws, regulations or orders or governmental action or
inaction (including failure, refusal or delay in issuing permits, approvals
and/or authorizations which is not the result of the action or inaction of the
party claiming such delay), riots, civil unrest or insurrection, war, terrorism,
bioterrorism, fire, earthquake, flood or other natural disaster, unusual and
unforeseeable delay which results from an interruption of any public utilities
(e.g., electricity, gas, water, telephone) including, without limitation,
utility service provider initiated "xxxxx-outs" or "black-outs". In no event
shall the inability to pay or other financial matter be considered a Force
Majeure Event. Under no circumstances shall the due date for the payment of Rent
or other amounts due under this Lease, or the obligation to pay Rent or other
amounts due under this Lease, be delayed or otherwise affected by a Force
Majeure Event.
28. SIGNS. Tenant shall be permitted to install an identification sign on each
floor of the Premises in the elevator lobby of such floor as well as adjacent to
Tenant's entry door on any other floors of the Premises. In addition, Tenant
shall be permitted to place Tenant's name, the name of each of Tenant's
professionals and other employees, and the name(s) of any Transferees or
successors of Tenant and their professionals and employees on the directory
board in the Building's lobby as well as any other directories on the Land or
any project of which the Building may be a part. During the Term of this Lease
(including all Extension Terms), Tenant shall have the exclusive right to
install building top and eyebrow signage on the exterior Building in accordance
with applicable Laws. Upon the termination of the Lease, at Tenant's sole cost
and expense, Tenant shall remove its building top signage from the Building and
repair any damage caused by such removal.
29. QUIET ENJOYMENT. Landlord covenants and agrees with Tenant that upon Tenant
paying the Rent required under this Lease and paying all other charges and
performing all of the covenants and provisions on Tenant's part to be observed
and performed under this Lease, Tenant may peaceably and quietly have, hold and
enjoy the Premises in accordance with this Lease without hindrance or
molestation by Landlord or its employees or agents.
-22-
30. EXTENSION OPTIONS.
(a) Subject to the terms of this Section 30, Landlord hereby grants to Tenant
two (2) options (the "Extension Option(s)") to extend the Term of this Lease
with respect to the entire Premises for five (5) years per Extension Option
(each, an "Option Term"), on the same terms, covenants and conditions as
provided for in this Lease during the initial Term, except that Monthly Base
Rent shall be established based upon the "fair market rental rate" for the
Premises for each Option Term as defined and determined in accordance with the
provisions of this Section 30 below. (In addition to the Monthly Base Rent,
additional rent shall be payable throughout each Option Term as provided in this
Lease.) An Extension Option may be exercised by Tenant, and Transferee of Tenant
or any of the parties described in Section 30(b) below.
(b) An Extension Option must be exercised, if at all, by written notice
("Extension Notice") delivered by Tenant to Landlord no later than six (6) full
calendar months prior to the expiration of the initial Lease term or the first
Option Term, as applicable. Once an Extension Notice is delivered, then the
extension of this Lease shall be binding.
(c) The term "fair market rental rate" as used in this Section 30 shall mean the
annual amount per rentable square foot, which as of the date of determination is
projected for and throughout the Option Term to be acceptable to a willing,
non-equity, non-renewal tenant of credit worthiness comparable to Tenant, and a
willing landlord of a comparable building of similar physical characteristics
within the North Creek/Canyon Park/Totem Lake submarket of Bothell, Washington
(the "Comparison Market"), in an arm's length transaction, leasing an entire
building, comparable in quality as the Premises, taking into account the triple
net nature of the Lease, the age and layout of the existing improvements in the
Premises and comparison leases and other items that professional real estate
brokers customarily consider, including, but not limited to, rental rates,
office space availability, tenant size and creditworthiness, tenant improvement
allowances, abatements, free rent, concessions, operating expenses and other
additional rent charges and allowance, and any other lease considerations, if
any, then being charged or granted by Landlord or the lessors of such similar
office buildings.
(d) Landlord shall provide written notice of Landlord's determination of the
fair market rental rate ("Landlord's Estimate") within thirty (30) days
following the exercise by Tenant of the applicable Extension Option. Tenant
shall have thirty (30) days ("Tenant's Review Period") after receipt of
Landlord's notice of Landlord's Estimate within which to accept such amount or
to object thereto in writing. Failure of Tenant to so object to Landlord's
Estimate in writing within Tenant's Review Period shall conclusively be deemed
Tenant's objection thereto. If Tenant objects to or is deemed to have objected
to the Landlord's Estimate, Landlord and Tenant will meet to present and discuss
their individual determinations of the fair market rental rate for the Premises
under the parameters set forth in Section 30(c) above and shall diligently and
in good faith attempt to negotiate a rental rate on the basis of such individual
determinations. Such meeting shall occur no later than ten (10) business days
after Tenant objects to, or is deemed to have objected to, Landlord's Estimate.
The Parties shall each provide the other with such supporting information and
documentation as they deem appropriate. At such meeting if Landlord and Tenant
are unable to agree upon the fair market rental rate, they shall each submit to
the other their respective best and final offer ("Final Offer") as to the fair
market rental rate. If Landlord and Tenant fail to reach agreement on such fair
market rental rate within five (5) business days following such a meeting (the
"Outside Agreement Date"), then each party's determination shall be submitted to
arbitration in accordance with the Section 33(n) below, subject to the provision
so of this Section 30(d). For ten (10) business days after the Outside Agreement
Date, Landlord and Tenant shall use good faith, commercially reasonable efforts
to select a mutually acceptable independent MAI appraiser or broker
("Appraiser") who has been active over the five-year period ending on the date
of such appointment in appraising buildings (or in the case of a broker,
commercial leasing) in the Comparison Market with comparable physical
characteristics to the Building and which has not been engaged by Landlord,
Tenant or any parent, subsidiary or affiliate thereof within the last three (3)
years. If Landlord and Tenant are not able to agree upon a mutually acceptable
Appraiser pursuant to the preceding sentence, then either Landlord or Tenant may
petition the Seattle, Washington office of JAMS to appoint an Appraiser
satisfying the requirements of the previous sentence. The method of arbitration
shall be that known as the "baseball" type of
-23-
arbitration: Each party shall submit to the Appraiser its Final Offer made
pursuant to this Section 30(d) in advance of the hearing. The Appraiser shall be
limited to awarding only one or the other of the two figures submitted. Landlord
and Tenant shall use commercially reasonable efforts to cause the Monthly Base
Rent for the Option Term to be determined at least thirty (30) days prior to the
start of the Option Term. The Appraiser's determination of the fair market
rental rate shall be binding on the parties.
31. ROOFTOP COMMUNICATION EQUIPMENT.
(a) Subject to the terms and conditions of this Lease, and at Tenant's sole
expense, during the Term of this Lease (including any Extension Terms) including
without limitation, Section 12, Landlord's approval of Tenant's plans, and
subject to all applicable Laws, Tenant shall have the non-exclusive right to
install, maintain and operate satellite and/or microwave dishes and/or antennae,
and related communications equipment ("Communication Equipment") on the roof of
the Building. Use of the roof top space shall be at no charge to Tenant during
the Term. Tenant reserves the right to run cabling, conduit or wiring across the
roof of the Building to and through appropriate conduit risers that will
terminate within the Premises as set forth in plans and specifications.
(b) Use of the roof top space shall only be for the use of Tenant (or any
assignee of this Lease under an assignment permitted by the terms of this
Lease). The rights to use the roof top space may not be granted to any other
party by assignment, lease, sublease, license, delegation or otherwise.
(c) This Section 31 shall not be construed as granting to Tenant the right to
use the roof for income producing purposes; all rights to use the roof for
purposes that would result in payment of rent, license fees or other amounts
from a third party shall belong exclusively to Landlord.
(d) Tenant shall indemnify and hold Landlord harmless from and against any loss,
cost, damage, claim or liability, including but not limited to the loss or
diminution of any warranties that Landlord may suffer as a result of Tenant's
actions under this Section 31, except for the active negligence or willful
misconduct of Landlord or a Landlord Party.
(e) On or before the expiration or termination of this Lease, Tenant shall
remove all such equipment and shall repair any damage resulting from such
removal so that the roof and Building systems are restored to the condition they
were in prior to the Tenant's use of the roof, ordinary wear and tear and
casualty damage excepted.
32. LANDLORD'S ACQUISITION OF LAND.
(a) PURCHASE AGREEMENT. Landlord represents and warrants that (i) that certain
Purchase and Sale Agreement dated March 3, 2005, by Creekside Building LLC, a
Washington limited liability company, as seller, and Xxxxxxxxxx Development LLC,
a Washington limited liability company, as buyer, as amended by that certain
letter agreement dated June 22, 2005 (as amended, the "Purchase Agreement") is
in full force and effect, (ii) true and correct copies of the Purchase Agreement
(including all amendments thereto) have been delivered to Tenant, (iii) Landlord
holds all right, title and interest of the buyer under the Purchase Agreement
pursuant to an assignment effected in accordance with the conditions of the
Purchase Agreement, and (iv) neither Landlord, as buyer, nor the seller under
the Purchase Agreement is in default in the performance of its obligations under
the Purchase Agreement nor does any act, condition or occurrence exist which,
with the giving of notice and/or the passing of time, would constitute a default
of buyer or seller under the Purchase Agreement. Landlord shall cause the
"closing" of Landlord's acquisition of the Purchase Agreement to occur by no
later than October 1, 2005.
(b) PROPERTY MATERIALS. Landlord represents and warrants that Landlord has
delivered, or shall promptly following execution of this Lease deliver, to
Tenant true, correct and complete copies of all documentation (if any) regarding
the physical condition and features of the Land and the Premises in Landlord's
possession, custody or control (the "Property Documentation"). The Property
Documentation shall include, without limitation, title reports and all
underlying title documents referenced therein, surveys
-24-
of the Land and the Building, all plans of the Building (including "as built"
plans), environmental reports, surveys and test results regarding the Building
and the Property as well as all manuals and other information and specifications
regarding building systems installed in the Building which were provided to
Landlord. As additional Property Documentation comes into Landlord's possession,
custody or control that has not been disclosed to Tenant, Landlord shall
promptly deliver complete copies of such Property Information to Tenant.
(c) EFFECTIVENESS. This Lease shall automatically become effective upon
Landlord's acquisition of the Premises. In the event that Landlord does not
acquire the Premises on or before October 1, 2005, then Tenant, in addition to
its rights and remedies hereunder or at law or in equity, may elect to terminate
this Lease by ten (10) business days' prior written notice to Landlord.
Provided, however, that if Landlord acquires the Premises prior to expiration of
such ten (10) business day period, then Tenant's termination right shall be
void. In the event that Tenant so terminates the Lease, then, as Tenant's sole
remedy, Landlord shall reimburse Tenant for the legal fees and expenses incurred
by Tenant in connection with the drafting and negotiation of this Lease.
33. MISCELLANEOUS.
(a) KEYS. Concurrently with its delivery of the Premises to Tenant pursuant to
Section 4(a) of the Lease, Landlord shall provide Tenant one (1) key to the
Premises for each 250 rentable square feet in the Building.
(b) CONFLICT OF LAWS. This Lease shall be governed by and construed solely
pursuant to the laws of the State of Washington, without giving effect to choice
of law principles thereunder.
(c) SUCCESSORS AND ASSIGNS. Except as otherwise provided in this Lease, all of
the covenants, conditions and provisions of this Lease shall be binding upon and
shall inure to the benefit of the Parties hereto and their respective heirs,
personal representatives, successors and assigns.
(d) ATTORNEYS' FEES. If either Landlord or Tenant should bring suit against the
other as a result of a default by the other party under this Lease, then the
defaulting party shall reimburse the reasonable attorneys' fees and litigation
expenses (including without limitation court costs) of the non-defaulting party.
(e) TERMS AND HEADINGS. The words "Landlord" and "Tenant" as used herein shall
include the plural as well as the singular. Words used in any gender include
other genders. The paragraph headings of this Lease are not a part of this Lease
and shall have no effect upon the construction or interpretation of any part
hereof.
(f) TIME. Time is of the essence with respect to the performance of every
provision of this Lease.
(g) PRIOR AGREEMENT; AMENDMENTS. This Lease constitutes and is intended by the
Parties to be a final, complete and exclusive statement of their entire
agreement with respect to the subject matter of this Lease. This Lease
supersedes any and all prior and contemporaneous agreements and understandings
of any kind relating to the subject matter of this Lease. There are no other
agreements, understandings, representations, warranties, or statements, either
oral or in written form, concerning the subject matter of this Lease. No
alteration, modification, amendment or interpretation of this Lease shall be
binding on the Parties unless contained in a writing which is signed by both
Parties.
(h) AUTHORITY. If either party executes this Lease as a corporation or
partnership, then such party represents and warrants that such entity is duly
qualified and in good standing to do business in Washington and that the
individuals executing this Lease on such party's behalf are duly authorized to
execute and deliver this Lease on its behalf, and in the case of a corporation,
in accordance with a duly adopted resolution of the board of directors of such
party, a copy of which is to be delivered to the other party on execution
hereof, if requested by the other party, and in accordance with the by-laws of
such
-25-
party, and, in the case of a partnership, in accordance with the partnership
agreement and the most current amendments thereto, if any, copies of which are
to be delivered to the other party on execution hereof, if requested by the
other party, and that this Lease is binding upon such party in accordance with
its terms.
(i) SEPARABILITY. The provisions of this Lease shall be considered separable
such that if any provision or part of this Lease is ever held to be invalid,
void or illegal under any law or ruling, all remaining provisions of this Lease
shall remain in full force and effect to the maximum extent permitted by law.
(j) COUNTERPARTS; COPY. This Lease may be executed in one or more counterparts,
each of which shall constitute an original and all of which shall be one and the
same agreement. A copy of a signed original of this Lease shall have the same
effect as a copy.
(k) LANDLORD'S LIABILITY; TRANSFER.
(i) Notwithstanding anything in this Lease to the contrary, covenants,
undertakings and agreements herein made on the part of Landlord in this Lease
are made and intended not as personal covenants, undertakings and agreements for
the purpose of binding Landlord personally or the assets of Landlord (except
Landlord's interest in the Premises, together with the rents, profits and
proceeds of the Premises), but are made and intended for the purpose of binding
only the Landlord's interest in the Premises, together with the rents, profits
and proceeds of the Premises as the same may from time to time be encumbered. No
personal liability or personal responsibility is assumed by Landlord, nor shall
at any time be asserted or enforceable against Landlord or Landlord Parties on
account of the Lease or on account of any covenant, undertaking or agreement of
Landlord in this Lease. If the entirety of Landlord's estate in the Premises is
sold, assigned or conveyed to any person or entity upon the exercise of any
remedy provided for in any mortgage, deed of trust, or by law or equity, such
person or entity and each person or entity thereafter succeeding to its interest
in the Premises: (a) shall not be liable for any act or omission of Landlord
under this Lease occurring prior to such sale or conveyance, except for (1)
continuing defaults which must be cured, and (2) offsets expressly permitted
under this Lease where the mortgagee or other beneficiary of a deed of trust
received written notice of the Landlord defaults giving rise to the offset
right, (b) shall not be bound by any payment prior to such sale or conveyance of
Rent or other payments for more than one month in advance, and (c) shall be
liable for the keeping, observance and performance of the other covenants,
agreements, terms, provisions and conditions to be kept, observed and performed
by Landlord under this Lease only during the period such person or entity shall
hold such interest.
(ii) In the event of any transfer or transfers of Landlord's interest in
the Premises, other than a transfer for security purposes only, the transferor
shall be automatically relieved of any and all obligations and liabilities on
the part of Landlord accruing from and after the date of such transfer and
Tenant agrees to attorn to the transferee; provided such transferee has
expressly, in writing, assumed all obligations and liabilities hereunder.
(l) FINANCIAL INFORMATION. If Tenant is not a publicly listed and traded
company, within ten (10) business days of receipt by Tenant of Landlord's
written request, but not more than once each year, Tenant shall deliver to
Landlord a copy of its most recent annual financial statements prepared in
accordance with generally accepted accounting principles, including a balance
sheet, income statement, statement of changes in stockholder's or owner's
equity, statement of cash flow, accompanying footnotes, and reports of
independent accountants; which reports may be consolidated with related
entities. Landlord shall hold Tenant's financial information in confidence and
agrees to execute a reasonable confidentiality agreement if so requested by
Tenant. In addition, Tenant shall provide Landlord with such financial
information on a non-consolidated basis (which will not be accompanied by
reports of an independent accountant) if the Landlord is in the process of
financing, re-financing or selling the property (and, in the case of a sale,
there is an executed written agreement for a sale and the buyer has requested
such financial information on a non-consolidated basis), provided that such
financial information may only be provided to a prospective purchaser or
mortgagee (and their representatives and agents), subject to the same
confidentiality requirements. Notwithstanding the foregoing, Tenant shall not be
required to
-26-
deliver non-consolidated financial reports if such non-consolidated financial
reports are not kept by Tenant in the ordinary course of its business.
(m) TITLE 51 WAIVER.
(i) TENANT HEREBY WAIVES ITS IMMUNITY WITH RESPECT TO LANDLORD UNDER THE
INDUSTRIAL INSURANCE ACT (RCW TITLE 51) AND/OR THE LONGSHOREMEN'S AND HARBOR
WORKER ACT, AND/OR ANY EQUIVALENT ACTS AND TENANT EXPRESSLY AGREES TO ASSUME
POTENTIAL LIABILITY FOR ACTIONS BROUGHT AGAINST LANDLORD BY TENANT'S EMPLOYEES,
EXCEPT TO THE EXTENT THAT THE LIABILITY ARISES AS A RESULT OF LANDLORD'S GROSS
NEGLIGENCE OR WILLFUL MISCONDUCT. THIS WAIVER HAS BEEN SPECIFICALLY NEGOTIATED
BY THE PARTIES TO THIS LEASE AND TENANT HAS HAD THE OPPORTUNITY TO, AND HAS BEEN
ENCOURAGED TO, CONSULT WITH INDEPENDENT COUNSEL REGARDING THIS WAIVER.
(ii) LANDLORD HEREBY WAIVES ITS IMMUNITY WITH RESPECT TO TENANT UNDER THE
INDUSTRIAL INSURANCE ACT (RCW TITLE 51) AND/OR THE LONGSHOREMEN'S AND HARBOR
WORKER ACT, AND/OR ANY EQUIVALENT ACTS AND LANDLORD EXPRESSLY AGREES TO ASSUME
POTENTIAL LIABILITY FOR ACTIONS BROUGHT AGAINST TENANT BY LANDLORD'S EMPLOYEES,
EXCEPT TO THE EXTENT THAT THE LIABILITY ARISES AS A RESULT OF TENANT'S GROSS
NEGLIGENCE OR WILLFUL MISCONDUCT. THIS WAIVER HAS BEEN SPECIFICALLY NEGOTIATED
BY THE PARTIES TO THIS LEASE AND LANDLORD HAS HAD THE OPPORTUNITY TO, AND HAS
BEEN ENCOURAGED TO, CONSULT WITH INDEPENDENT COUNSEL REGARDING THIS WAIVER.
(n) ARBITRATION. If this Lease provides that a matter is to be subject to
arbitration, then the matter shall be settled by arbitration in Seattle,
Washington, pursuant to the arbitration rules and procedures set forth in RCW
7.04, with a single arbitrator. The arbitrator shall be a person having at least
ten (10) years' experience and knowledge about commercial leasing and property
management. Each party shall pay the cost of its experts and attorneys. The
costs of the arbitrator shall be shared equally by the parties. The prevailing
party shall be entitled to an award of reasonable attorney's fees. The
arbitrator's award shall be final and binding on the parties.
[SIGNATURES ON FOLLOWING PAGE]
-27-
IN WITNESS WHEREOF, the Parties have caused this Lease to be duly executed
by their duly authorized representatives as of the date first above written.
TENANT: LANDLORD:
EMULEX DESIGN & MANUFACTURING 24000 Development LLC, a Washington
CORPORATION, a Delaware corporation limited liability company
By: _________________________________ By: _______________________________
Print Name: _____________________ Xxxxxxx Xxxxxxxxxx, Manager
Print Title: ____________________
By: _________________________________
Print Name: _____________________
Print Title: ____________________
-28-
STATE OF _________________ )
)ss.
COUNTY OF ________________ )
I certify that I know or have satisfactory evidence that______________ and
_________________________________________ are the persons who appeared before
me, and said persons acknowledged that they signed this instrument, on oath
stated that they were authorized to execute the instrument and acknowledged it
as the ____________________________ and ________________________ respectively of
EMULEX DESIGN & MANUFACTURING CORPORATION, a Delaware corporation, to be the
free and voluntary act of such party for the uses and purposes mentioned in the
instrument.
Dated: August _____, 2005.
______________________________________
(Signature of Notary Public)
______________________________________
(Printed Name of Notary Public)
residing in __________________________
My Appointment expires _______________
STATE OF WASHINGTON )
)ss.
COUNTY OF KING )
I certify that I know or have satisfactory evidence that Xxxxxxx
Xxxxxxxxxx is the person who appeared before me, and said person acknowledged
that he signed this instrument, on oath stated that he was authorized to execute
the instrument and acknowledged it as the Manager of 24000 Development LLC, a
Washington limited liability company, to be the free and voluntary act of such
party for the uses and purposes mentioned in the instrument.
Dated: August _____, 2005.
______________________________________
(Signature of Notary Public)
______________________________________
(Printed Name of Notary Public)
residing in __________________________
My Appointment expires _______________
-29-
EXHIBIT "A"
LEGAL DESCRIPTION OF LAND
Lot 6, QUADRANT XXXXX XXXXX CENTER, according to the Plat thereof recorded in
Volume 54 of Plats, Pages 165 through 169, inclusive, in Snohomish County,
Washington.
EXHIBIT "A"
-1-
EXHIBIT "B"
WORK LETTER AGREEMENT
(LANDLORD BUILD W/ALLOWANCE)
This WORK LETTER AGREEMENT ("Work Letter Agreement") is entered into as of the
___ day of August, 2005, between 24000 DEVELOPMENT LLC, a Washington limited
liability company ("Landlord"), and EMULEX DESIGN & MANUFACTURING CORPORATION, a
Delaware corporation ("Tenant"), with reference to the following recitals:
A. Concurrently with the execution of this Work Letter Agreement, Landlord and
Tenant have entered into a lease (the "Lease") covering certain premises
("Premises") more particularly described in Exhibit "A" attached to the Lease.
All terms not defined herein have the same meaning as set forth in the Lease. To
the extent applicable, the provisions of the Lease are incorporated herein by
this reference.
B. In order to induce Tenant to enter into the Lease and in consideration of the
mutual covenants hereinafter contained, Landlord and Tenant hereby agree as
follows:
1. PREPARATION OF CONSTRUCTION DRAWINGS.
(a) Selection of Architect and Engineers. After the execution of this
Lease, Landlord shall engage JPC Architects, P.L.L.C. ("Architect") to prepare
the Space Plan (defined below) for the Tenant Improvements (defined below). With
consultation from Tenant and Architect, Landlord shall select and retain
engineering consultants (the "Engineers") to prepare the Working Drawings
(defined below), which shall be consistent with the Approved Space Plan and
include without limitation all plans and engineering working drawings relating
to the structural, mechanical, electrical, plumbing, HVAC, life/safety, and
sprinkler work in connection with the Tenant Improvements. Prior to the
execution of any agreement engaging the Architect or any of the Engineers,
Landlord shall submit such agreement to Tenant for Tenant's review, comment and
approval, which approval shall not be unreasonably withheld, conditioned or
delayed; provided, however, the provisions of such contracts pertaining to the
recourse of Landlord against Architect and Engineers shall be subject to
Tenant's approval to be exercised in Tenant's sole and absolute good faith
discretion. Landlord may not enter into an agreement with Architect or any of
the Engineers unless such agreement has been approved in writing by Tenant
pursuant to this Section. Landlord shall not amend any contract between Landlord
and the Architect or the Engineers in such a manner that would adversely affect
Tenant's recourse against Architect or the Engineers under the Design and
Construction Warranties (defined below) to be assigned to Tenant pursuant to
Section 4(d) of this Work Letter Agreement, or increase the hourly rates charged
by Architect or the Engineers in performing the Landlord's Work.
(b) Space Plan. On or before the date therefor specified in the Work
Schedule attached hereto as Exhibit "B-1" ("Work Schedule"), Architect shall
prepare and deliver to Landlord and Tenant for their respective approval four
(4) copies of the space plan for all Tenant Improvements in the Premises ("Space
Plan"), which Space Plan shall be prepared consistent with Tenant's directions
and other instructions to Architect and further shall reflect a layout and
description of all offices, rooms and other partitions, their intended use, and
the equipment to be contained therein. Landlord or Tenant may request reasonable
clarification or more specific drawings reasonably required for special use
items not included in the Space Plan. Landlord or Tenant shall, no later than
the deadline specified in the Work Schedule, (i) approve the Space Plan, or (ii)
approve the Space Plan subject to specified conditions to be complied with in
connection with the Working Drawings (defined below). Landlord and Tenant shall
use good faith, commercially reasonable efforts to resolve any disputes that may
arise between Landlord and Tenant regarding any conditions imposed pursuant to
subpart (ii) of this Section 1(b). The Space Plan, as approved by Landlord and
Tenant pursuant to this Section 1(b) (including the revisions required in
EXHIBIT "B"
-1-
connection with a conditional approval), shall be referred to in this Work
Letter Agreement as the "Approved Space Plan."
(c) Working Drawings. Based upon the Approved Space Plan, by the date
specified in the Work Schedule, Landlord shall cause the Engineers to complete
and deliver to Tenant for Tenant's approval, two (2) copies of complete, fully
coordinated architectural and (to the extent required) structural, mechanical,
electrical and plumbing working drawings and specifications for the Tenant
Improvements for the Premises in a form which is sufficiently complete to allow
the Contractor and all subcontractors to bid on the work shown therein and to
obtain all applicable Permits (defined below) therefor (collectively, the
"Working Drawings"). The Working Drawings shall be consistent with the Approved
Space Plan. Tenant shall, by the date specified in the Work Schedule, either (i)
approve the Working Drawings, (ii) approve the Working Drawings subject to
specified conditions to be satisfied by Landlord prior to submission of the same
by Landlord for the Permits, or (iii) disapprove and return the same to Landlord
with required revisions. If Tenant disapproves the Working Drawings, within
three (3) business days of receipt of such disapproval, Landlord shall cause the
Architect to make all changes thereto required to satisfy Tenant's required
revisions and shall resubmit to Landlord such revised Working Drawings, and
Landlord shall, within three (3) business days after Tenant receives such
resubmitted Working Drawings, approve, approve with conditions, or disapprove
the resubmitted Working Drawings, with the foregoing procedure to be repeated
until the Working Drawings are ultimately approved by Tenant. The Working
Drawings, as approved by Tenant pursuant to this Section 1(c) shall be referred
to in this Work Letter Agreement as the "Approved Working Drawings." Landlord
shall cause the process of preparing and approving the Working Drawings to be
completed by such a time that will not delay Landlord's submission of the bid
materials and Approved Working Drawings to the Bidding Contractors with
sufficient time for such Bidding Contractors to prepare bids for the
construction of the Tenant Improvements, and for Landlord to review, analyze and
deliver to Tenant a detailed written recommendation regarding the bids of the
Bidding Contractors, by no later than September 27, 2005.
(d) Changes in Approved Working Drawings. In the event Tenant desires to
change any set of Approved Working Drawings, Tenant shall deliver a notice (a
"Drawing Change Notice") of such proposed change to Landlord, which Drawing
Change Notice shall set forth in detail all changes (the "Tenant Changes")
Tenant desires to make to the Approved Working Drawings. To the extent that
drawings or depictions of the proposed Tenant Changes are reasonably required by
Landlord, then Tenant shall instruct Architect and/or the Engineers, as may be
applicable, to prepare drawings setting forth in reasonable detail the proposed
Tenant Changes. Landlord shall, within three (3) business days following
Landlord's receipt of any Drawing Change Notice either: (i) approve the Tenant
Changes in question, or (ii) disapprove such Tenant Changes and deliver a notice
to Tenant specifying in reasonably sufficient detail the reasons for Landlord's
disapproval. Notwithstanding anything to the contrary herein, Landlord may not
withhold its consent to Tenant Changes where Tenant, subject to funding from any
remaining unspent portion of the Tenant Improvement Allowance, agrees to bear
the increased cost of the construction of the Tenant Improvements directly
resulting from the Tenant Changes. If the Contractor has already been engaged by
Landlord at the time Tenant requests a Tenant Change, Landlord shall use
commercially reasonable efforts to negotiate a change order to the construction
contract between Landlord and the Contractor consistent with the Tenant Change
upon the best possible terms and conditions for the Tenant. Subject to funding
from any remaining unspent portion of the Tenant Improvement Allowance, Tenant
shall bear (A) the cost of the Architect and Engineers incurred as a result of
revising the Approved Working Drawings to effect any Tenant Change, and (B) the
cost of construction of the Tenant Improvements that are the subject of the
Tenant Change.
(e) Tenant Improvements; Standards for Approval. The term "Tenant
Improvements" means all initial improvements, fixtures and equipment to be
permanently affixed to the Premises pursuant to this Work Letter Agreement. The
term "Landlord's Work" shall mean and refer to the work and activities performed
by, or caused to be performed by, Landlord in connection with the construction
of the Tenant Improvements pursuant to this Work Letter Agreement. Except as
provided otherwise herein, each time Landlord or Tenant is granted the right
under this Work Letter Agreement to review, consent or approve the Space Plan,
the Working Drawings, any part or component thereof, or any proposed Tenant
Change (each such approval is referred to herein as a "Consent"), such Consent
shall not be not be withheld or
EXHIBIT "B"
-2-
conditioned unless the proposed improvements (i) would unduly burden the
Building's operating systems or (ii) would fail to comply with applicable laws,
codes, ordinances or regulations.
(f) Permits. By no later than the date specified in the Work Schedule,
Landlord shall cause the Engineers to prepare updated versions of the Space
Plans containing sufficient information to submit to the City of Bothell to
apply for and obtain the Permits. Such plans and drawings shall be referred to
in this Work Letter Agreement as the "Permit Drawings." By no later than the
date specified in the Work Schedule, Landlord shall submit to the appropriate
governmental entities the Approved Space Plans (including such additional
reasonable detail as is customarily required by the applicable governmental
entities) and Landlord shall otherwise apply for all applicable building and
other permits and approvals (collectively, "Permits") necessary or required for
the Contractor to commence, perform and fully complete the construction of the
Tenant Improvements (and to permit Tenant to legally occupy the Premises). If
the governmental entities reviewing the applications for permits and related
materials require any revisions to the Permit Drawings, Landlord shall cause
such revisions to be made within five (5) business days and delivered to Tenant
for its approval in accordance with the same procedures for Tenant's review and
approval of the Working Drawings in accordance with Section 1(c) above.
Revisions to the Permit Drawings made in connection with responding to the
request of a governmental agency pursuant to the preceding sentence shall not
constitute a Tenant Change, notwithstanding any provision of this Work Letter to
the contrary. In addition to its covenants in the preceding sentence, Landlord
shall use good faith, commercially reasonable and diligent efforts to cause all
of the Permits to be fully issued (in "ready to issue" form) on or before the
date specified therefor in the Work Schedule. Neither Landlord nor any (i)
Landlord Party shall have any obligation or liability to Tenant if any Permit
(including, without limitation, any building permit, certificate of occupancy,
or equivalent) is not timely issued to Landlord, provided that Landlord has
applied for such Permits in accordance with the Work Schedule, (ii) Landlord has
exercised good faith, commercially reasonable and diligent efforts to cause the
Permits to be issued in accordance with the Work Schedule, and (iii) the delay
in the issuance of the Permits has not been caused by the negligence or willful
misconduct of Landlord or any Landlord Parties. As used herein, "Landlord Party"
shall mean Landlord and its partners, advisors, lenders and each of their
respective officers, managers, directors, employees, contractors, agents,
architects, engineers, successors and assigns.
2. COST OF TENANT IMPROVEMENTS.
(a) Allocation of Costs. Landlord shall bear all Tenant Improvement Costs
(defined below) to the extent that the total Tenant Improvement Costs do not
exceed the Tenant Improvement Allowance set forth in Section 1(l) of the Lease
(as the same may be increased pursuant to the terms and conditions of the
Lease). Tenant shall bear all Tenant Improvement Costs in excess of the Tenant
Improvement Allowance ("Excess Costs") in accordance with the provisions of this
Work Letter Agreement.
(b) Payment of Excess Costs by Tenant. Excess Costs shall be paid by
Tenant to Landlord, on a proportionate basis promptly upon request from
Landlord, as Landlord incurs such costs after the Tenant Improvement Allowance
has been paid in full by Landlord in accordance with this Work Letter Agreement.
Tenant shall pay Landlord for Excess Costs incurred by Landlord in connection
with the design and construction of the Tenant Improvements pursuant to this
Section 2(b) within five (5) business days following Landlord's request
therefor, which request shall be accompanied by reasonable supporting
documentation (e.g., as set forth on invoices paid or payable by Landlord as of
such date). Notwithstanding anything in this Work Letter Agreement or the Lease
to the contrary, Landlord shall have the right to discontinue its performance of
the Landlord's Work until such time as Tenant complies with the requirements of
this Section 2(b). If Tenant fails to pay Excess Costs when due hereunder, the
unpaid Excess Costs shall accrue interest from the due date at a rate of twelve
percent (12%) per annum, simple interest.
EXHIBIT "B"
-3-
(c) Disbursement of Tenant Improvement Allowance.
(i) Definition of Tenant Improvement Costs. As used herein, "Tenant
Improvement Costs" shall mean the actual, out-of-pocket costs incurred by
Landlord in performing the Landlord's Work, preparing the Space Plan and Working
Drawings and obtaining the Permits.
(ii) Exclusions from Tenant Improvement Costs. Notwithstanding
Section 2(c)(i) above or any other provision of the Lease or this Work Letter
Agreement to the contrary, Tenant Improvement Costs shall not include any of the
following costs and expenses (collectively, the "Excluded Costs"): (A) costs for
the Base Building Work; (B) costs incurred in the inspection, testing, removal,
abatement or remediation of Hazardous Materials to the extent that such costs
are incurred by Landlord in the performance of Landlord's obligations under the
Lease; (C) any breaches of Landlord's covenants, representations and warranties
set forth in the Lease or this Work Letter Agreement; (D) the cost of work
performed prior to the execution of the Lease or which is not authorized by the
Lease or this Work Letter Agreement; (E) costs that are recovered or are
reasonably recoverable from a third party (e.g., insurers, warrantors or
tortfeasors); (F) construction management fees incurred by Landlord or any party
acting on behalf of Landlord in excess of the lesser of (1) an arms' length rate
or (2) five percent (5%) of the Tenant Improvement Costs; and (G) profit and
overhead charges paid to Landlord or any person controlled by, controlling or
under common control with Landlord. The Excluded Costs shall be borne by
Landlord (or, as may be applicable, Contractor or any other third party) at its
sole cost and expense, without reimbursement from the Tenant Improvement
Allowance.
(iii) Disbursement. Landlord shall have the right to disburse the
Tenant Improvement Allowance for such Tenant Improvement Costs in accordance
with the provisions of this Work Letter Agreement and in such order as Landlord
shall determine; provided, however, notwithstanding anything in this Work Letter
Agreement to the contrary, Landlord shall not be authorized to incur, or pay any
portion of the Tenant Improvement Allowance, overtime wages or like changes to
contractor (or any subcontractors) in connection with the construction of the
Tenant Improvements, unless such overtime has been authorized by Tenant in
writing prior to being incurred, which authorization may be given or withheld in
Tenant's sole and absolute discretion. Tenant shall have the right to apply any
portion of the Tenant Improvement Allowance to Tenant's actual, out-of-pocket
expenses (including fees and reimbursable expenses, where applicable) of
Tenant's Agents (defined below), including without limitation, the following
types of fees, costs and expenses: (A) Tenant's third-party construction
manager, (B) purchasing and installing cabling, conduits and/or data or
telecommunications wiring, (C) the design, construction and installation of
Tenant's signage, (D) Tenant's security system and related equipment and the
installation thereof, (E) relocation and moving costs in connection with
Tenant's relocation and move-in to the Premises, (F) movable and built-in
furniture, (G) trade fixtures and other fixtures, (H) modifications or
improvements to the landscaping of the Premises, (I) interior and landscape
design services, (J) Tenant's enforcement of the Design and Construction
Warranties against Architect, the Engineers and/or the Contractor (and any of
Contractor's subcontractors or suppliers), and (K) other interior decorations
intended to be used or installed by Tenant at the Premises. As used herein,
"Tenant's Agents" shall mean collectively, the all contractors, subcontractors,
laborers, materialmen, suppliers and other third-parties directly retained by
Tenant in connection with the design and construction of the Tenant
Improvements, Tenant's relocation to the Premises and (after the date of
Substantial Completion) Tenant's use and occupancy of the Premises. In the event
that, (1) Tenant desires Landlord to disburse the Tenant Improvement Allowance
for Tenant Improvement Costs payable directly by Tenant and (2) in Landlord's
commercially reasonable judgment, the Tenant Improvement Allowance is sufficient
to cover the (a) amount of the Tenant Improvement Costs to be incurred by
Landlord and (b) the amounts desired to be so disbursed by Tenant, Landlord
shall make such disbursements to Tenant pursuant to this Section 2(c)(iii).
Landlord shall not be required to make more than one such disbursement to Tenant
per calendar month and then only if on or before the twenty-fifty (25th) day of
the preceding calendar month, Tenant delivers to Landlord (i) a request for
payment substantially in the form of AIA Document G702, (ii) invoices from all
of Tenant's Agents covered by
EXHIBIT "B"
-4-
Tenant's request for disbursement, (iii) executed mechanic's lien releases from
all of such Tenant's Agents that are entitled to lien rights; and (iv) all other
information reasonably requested by Landlord. Tenant's request for payment shall
be deemed Tenant's acceptance and approval of the work furnished and/or the
materials supplied as set forth in Tenant's payment request vis-a-vis the
Landlord. Provided that such request for disbursement (and the work covered
hereby) is, in Landlord's commercially reasonable judgment, not defective or
deficient, on or before the last day of the calendar month following Landlord's
receipt of such request, Landlord shall deliver a check to Tenant made payable
to either Tenant's Agent or Tenant (at the election of Landlord), in the amount
requested to be disbursed by Tenant. Landlord's payment of such amounts shall
not be deemed Landlord's approval or acceptance of the work furnished (or
materials supplied, if any) as set forth in Tenant's payment request.
3. CONSTRUCTION.
(a) Base Building Work. Landlord, at its sole cost and expense, without
deduction or reimbursement from the Tenant Improvement Allowance, shall perform
the following work (the "Base Building Work"): (i) cause the Building to have
the capacity to provide at least 6.86 Xxxxx per rentable square foot of
electrical current to the Premises; (ii) cause the Building to have HVAC
capacity of at least one hundred fifteen (115) tons; (iii) cause the Building to
have HVAC zoning of not less than one (1) zone for every one thousand (1,000)
usable square feet in the Premises; (iv) cause the Building's existing structure
to be in good condition and repair; (v) cause the Building's existing operating
systems to be in good condition and working order; (vi) cause the Building and
Exterior Areas (but excluding the Tenant Improvements) to be brought into
compliance with all applicable laws, regulations, codes and ordinances,
including without limitation the ADA; and (vii) cause all Hazardous Materials
present in the Premises to be removed, remediated or otherwise treated to the
extent necessary to comply with Section 7(c)(ii) of the Lease. Landlord shall be
solely responsible for any delays in achieving Substantial Completion by
December 12, 2005 on a critical path basis to the extent arising from Landlord's
obligation to perform the Base Building Work.
(b) Construction Contract. By no later than the date specified in the Work
Schedule, Landlord shall present to Tenant Landlord's form construction
contract, on a cost-plus fee basis with a guaranteed maximum price, or at
Tenant's option a lump sum basis. Within three (3) business days after Tenant's
receipt of such draft construction contract, Tenant shall provide Landlord with
Tenant's comments to the draft construction contract and thereafter Landlord and
Tenant shall use good faith, commercially reasonable efforts to agree on the
form of a construction contract to be used for the construction of the Tenant
Improvements that is mutually acceptable to Landlord and Tenant by no later than
September 16, 2005; provided, however, the provisions of such construction
contract pertaining to Landlord's remedies against contractor (and all
subcontractors engaged pursuant to such construction contract) shall be subject
to Tenant's approval in Tenant sole and absolute discretion exercised in good
faith. Such approved construction contract shall be referred to herein as the
"Construction Contract". Landlord shall deliver the Construction Contract to
each of the Bidding Contractors (defined below) as part of Landlord's Request
for Proposal (defined below).
(c) Request for Proposal. By no later than the date specified in the Work
Schedule, Landlord shall present to Tenant Landlord's proposed request for
proposal to be submitted to each of the Bidding Contractors. Within three (3)
business days after Tenant's receipt of such draft request for proposal, Tenant
shall provide Landlord with Tenant's comments to the draft request for proposal
and thereafter Landlord and Tenant shall use good faith, commercially reasonable
efforts to agree on the form of a request for proposal to be submitted to the
Bidding Contractors by no later than September 16, 2005. Such approved request
for proposal shall provide that each contractor shall achieve Substantial
Completion of the Premises and the Tenant Improvements by no later than December
12, 2005, and further shall be referred to herein as the "Request for Proposal".
Landlord shall deliver the Request for Proposal to each of the Bidding
Contractors.
(d) Selection of Contractor. Immediately upon Tenant's approval of the
Working Drawings, Landlord shall submit the Approved Working Drawings together
with the Construction Contract and the Request for Proposal in connection with
the construction of the Tenant Improvements to three (3)
EXHIBIT "B"
-5-
prospective general contractors selected by Landlord, or at Tenant's election,
two (2) prospective general contractors selected by Landlord and one (1)
prospective general contractor selected by Tenant (such prospective general
contractors, the "Bidding Contractors"). Upon receipt of such bids for the
general conditions and fee from such Bidding Contractors in connection with the
performance of the Tenant Improvements, but no later than the date specified in
the Work Schedule, Landlord shall deliver a written recommendation to Tenant
regarding which of the Bidding Contractors should be selected to perform the
Landlord's Work, which written recommendation shall specify the following cost
estimates (the "Bid Estimate"): (i) the total amount of Tenant Improvement Costs
to be incurred under the recommended bid in connection with the performance of
the Landlord's Work and (ii) the total Excess Costs, if any, to be incurred in
connection with such proposal in accordance with Section 2(a) above. Landlord
shall use its best, good faith efforts to confer and advise Tenant regarding the
selection of the Bidding Contractor. By no later than the date specified in the
Work Schedule, Landlord and Tenant shall select a Bidding Contractor to perform
the Landlord's Work required pursuant to this Work Letter Agreement, which
Bidding Contractor shall be mutually acceptable to Landlord and Tenant (the
"Contractor"). Promptly upon receipt of such notice, Landlord shall retain and
engage the Contractor and shall cause the Contractor to mobilize for the
construction of the Tenant Improvements and commence the construction of the
Tenant Improvements by no later than the date specified in the Work Schedule.
After the engagement of Contractor by Landlord pursuant to this Work Letter
Agreement, if Contractor subsequently requests any change order or amendment to
the Construction Contract between Contractor and Landlord ("Change Order
Request"), Landlord shall promptly forward such Change Order Request to Tenant
and Landlord shall not execute or otherwise authorize any Change Order Request
unless Tenant has approved such Change Order Request in writing, which approval
may be withheld in Tenant's sole and absolute discretion exercised in good
faith.
(e) Delivery of Approved Working Drawings and Permits. Promptly after the
receipt of the Permits, Landlord shall deliver to Tenant copies of the
following: (i) two (2) copies of the plans and specifications approved by the
applicable governmental entities (which plans and specifications shall have been
prepared and approved in accordance with the terms and conditions of this Work
Letter Agreement) stamped as approved by the applicable governmental entities
and (ii) "ready to issue" documents from applicable governmental entities with
respect to all Permits necessary or required for the Contractor to commence,
perform and fully complete the construction of the Tenant Improvements.
(f) Record Set of Drawings. After Substantial Completion, Landlord shall
cause the Architect to prepare and deliver to Landlord and Tenant two (2)
complete sets of reproducible copies (and one (1) complete set of AutoCad ".dwg"
(release 13 or higher) files) of the as-built documents for the Tenant
Improvements.
4. SUBSTANTIAL COMPLETION.
(a) Early Occupancy. If Tenant occupies all or any portion of the Premises
or otherwise installs furniture, fixtures or equipment prior to Substantial
Completion (except for work performed by Contractor as part of the Tenant
Improvements), Tenant shall not unreasonably impede or otherwise disrupt the
Substantial Completion of the Tenant Improvements.
(b) Substantial Completion. Landlord shall cause the Contractor to achieve
the Substantial Completion of the Tenant Improvements by the date specified in
the Work Schedule. For purposes of this Lease, "Substantial Completion" of the
Premises and the Tenant Improvements shall have been achieved upon the
occurrence of each of the following: (i) the substantial completion of
construction of the Tenant Improvements in accordance with the Approved Working
Drawings, with the exception of any Punch List Items (defined in Section 4(c)
below); (ii) the Architect has delivered a written certification to Tenant that
Substantial Completion has been achieved; (iii) the issuance of a certificate of
occupancy (or equivalent sign-off or approval) from the City of Bothell or other
governmental entity with jurisdiction permitting the full use and occupancy of
the Premises for the purposes permitted under the Lease; (iv) all Base Building
Work is complete and all utilities serving the Premises are operational; (v) all
Building operating and mechanical systems are in good condition and working
order; and (vi) the Premises otherwise are in such a condition so as to
reasonably permit Tenant's use and occupancy of the Premises for Tenant's
ordinary
EXHIBIT "B"
-6-
business purposes. Terms like "Substantially Complete", "Substantially
Completing" and other phrases of like impart shall be deemed to be references to
the Substantial Completion of the Premises and the Tenant Improvements.
(c) Preparation of Punch List. Once Substantial Completion has occurred,
Landlord shall give Tenant five (5) business days prior notice of a meeting for
Tenant to inspect the Tenant Improvements. Tenant's representative and Architect
shall completely examine the Premises and Tenant's representative and the
Architect shall prepare a list (the "Punch List") of all Punch List Items
(defined below). The list shall be signed by Landlord, Tenant and Landlord's
Contractor and all items shall be completed as soon as reasonably possible
thereafter. Tenant's execution of the Punch List shall not be deemed to be a
waiver of warranty or any of Tenant's rights in connection with defects to the
Tenant Improvements. As used herein, "Punch List Items" shall mean all items of
construction which entail one or more details of construction, decoration,
mechanical adjustment or installation that do not materially and adversely
affect the use and occupancy of any portion of the Premises for the normal
conduct of Tenant's business.
(d) Assignment of Rights and Warranties. Effective upon final completion
of the Tenant Improvements, Landlord shall assign to Tenant (i) all rights and
recourse of Landlord against Architect pursuant to the agreement between
Landlord and Architect for the design of the Tenant Improvements, (ii) all
rights and recourse of Landlord against all Engineers pursuant to the agreement
between Landlord and such Engineers for the design of the Tenant Improvements,
and (iii) all rights and recourse of Landlord against Contractor pursuant to the
Construction Contract (including without limitation warranties and guaranties
made by Contractor relating to the Tenant Improvements) (collectively, the
"Design and Construction Warranties"), pursuant to an assignment in form
reasonably acceptable to Tenant. Landlord shall obtain all costs of Architect,
the Engineers and Contractor required to effect the assignment of the Design and
Construction Warranties to Tenant. After the effective date of the assignment of
the Design and Construction Warranties to Tenant, Landlord shall cooperate with
Tenant's attempts to enforce the Design and Construction Warranties against
Architect, the Engineers and/or Contractor; provided, however, Landlord shall
have no obligation to incur any out of pocket expenses in connection with such
cooperation. Prior to the assignment of the Design and Construction Warranties
to Tenant pursuant to the preceding sentence, Landlord shall use diligent, good
faith efforts to cause Contractor to use construct the Tenant Improvements in
accordance with the Construction Contract and free from defects. In the event
that Landlord discovers or otherwise determines that any portion of the Tenant
Improvements has not been constructed in accordance with the Contraction
Contract or otherwise is defective, Landlord shall promptly notify Tenant in
writing.
5. DELAY.
(a) Tenant Delay. Delays in the achievement of Substantial Completion by
December 12, 2005 on a critical path basis caused by any of the following shall
constitute a "Tenant Delay": (i) Tenant fails to perform any of its obligations
set forth in this Work Letter Agreement by the time deadline set forth in the
Work Schedule or the deadline set forth in this Work Letter Agreement; (ii)
Tenant's request for, and Landlord's implementation and construction of, Tenant
Changes; (iii) any request by Tenant that Landlord delay the completion of any
component of the Landlord's Work; (iv) any breach or default by Tenant in the
performance of Tenant's obligations under this Work Letter Agreement or the
Lease; (v) Tenant's failure to pay amounts when due under this Work Letter
Agreement; or (vi) any unreasonable delay resulting from Tenant's having taken
possession of the Premises for any reason, or Tenant's installation of fixtures,
furniture and equipment (except for work performed by Contractor as part of the
Construction Contract), prior to the Substantial Completion of the Landlord's
Work. The Commencement Date shall be accelerated to the date that Landlord would
have achieved Substantial Completion but for the Tenant Delay.
(b) Permit Delay. As used herein, "Permit Delay" shall mean delays in the
achievement of Substantial Completion by December 12, 2005 on a critical path
basis caused by Landlord's failure to obtain the Permits for reasons beyond
Landlord's reasonable control, despite Landlord's exercise of commercially
reasonable, good faith and diligent efforts, to obtain the Permits when required
pursuant to
EXHIBIT "B"
-7-
the Work Schedule. Landlord and Tenant shall cooperate to minimize and mitigate
potential Permit Delays including without limitation by performing pre-permit
work in connection with the construction of the Tenant Improvements to the
extent feasible. Permit Delay shall not constitute Tenant Delay. Permit Delay
shall not operate to cause the acceleration of the Commencement Date.
(c) Tenant Option to Accelerate. Upon the occurrence of any Permit Delay
or any Force Majeure Delay, but subject to Landlord's covenants in Section 5(b)
of this Work Letter Agreement, Landlord shall promptly notify Tenant and Tenant
may elect, in its sole discretion, to authorize the payment of overtime, the
rescheduling of the performance of different components of the Landlord's Work,
to initiate Tenant Changes or to take other measures to mitigate the effect of
the Permit Delay or the Force Majeure Delay (collectively, "Tenant Acceleration
Elections"). Subject to funding from any remaining unspent portion of the Tenant
Improvement Allowance, Tenant shall bear any increases in Tenant Improvement
Costs resulting from Tenant Acceleration Elections.
6. MISCELLANEOUS.
(a) Risk of Loss. Landlord shall not commence the construction of the
Tenant Improvements without Landlord's general contractor first acquiring "all
risks" builders' risk insurance covering all of the Landlord's Work and the
minimum insurance coverages specified in Exhibit "B-2" attached hereto.
(b) Construction Representatives. Landlord hereby appoints the following
person(s) as Landlord's representative ("Landlord's Representative") to act for
Landlord in all matters covered by this Work Letter Agreement: Xxxx Xxxx of Xxxx
Xxxx Associates, Inc., 0000 XX 000xx Xxxxxx, Xxxx Xxxxxx Xxxx, Xxxxxxxxxx 00000,
telephone: (000) 000-0000, fax: (000) 000-0000. Tenant hereby appoints the
following person as Tenant's representative ("Tenant's Representative") to act
for Tenant in all matters covered by this Work Letter Agreement: Xxxxx Xxxxxxx,
0000 Xxxxx Xxxxxx, Xxxxx Xxxx, Xxxxxxxxxx 00000, telephone: (000) 000-0000, fax:
(000) 000-0000. A copy of all communications to Tenant's Representative shall
also be sent to Xxxxxxx, Inc., 00000 Xxx Xxxxxx Xxxxxx, Xxxxxx, Xxxxxxxxxx
00000, Attention: Xxxxx Xxxxxx, telephone: (000) 000-0000, fax: (000) 000-0000.
All communications with respect to the matters covered by this Work Letter
Agreement are to be made to Landlord's Representative or Tenant's
Representative, as the case may be (with copies delivered as provided above), in
writing in compliance with the notice provisions of the Lease (but to the
addresses set forth above). Either party may change its representative under
this Work Letter Agreement at any time by written notice to the other party in
compliance with the notice provisions of the Lease.
(c) Records. Landlord shall maintain, and shall cause the general
contractor to maintain, complete and correct books and records relating to the
construction of the Tenant Improvements and the performance of the Landlord's
Work and all Tenant Improvement Costs (collectively, the "Construction
Records"). All records and accounts relating to such matters shall be in a
format consistent with standard accounting practices. After the final completion
of the Tenant Improvements, Landlord shall deliver copies of the Construction
Records to Tenant.
(d) Arbitration. In the event that a dispute arises between Landlord and
Tenant regarding the parties' obligations under this Work Letter Agreement or
the construction of this Work Letter Agreement, then such dispute shall be
resolved by binding arbitration in accordance with Section 33(n) of the Lease.
If Substantial Completion of the Tenant Improvements has not occurred at the
time such dispute arises, Landlord and Tenant shall utilize any expedited
dispute resolution rules and procedures that may be available.
(e) Damage Caused by Tenant. In the event that Tenant or Tenant's Agents
(excluding Architect, the Engineers, Contractor and its subcontractors and
suppliers) damage the Premises or the Tenant Improvement work being performed by
Contractor as a result of Tenant's or such Tenant's Agents' activities on the
Premises prior to Substantial Completion, then Tenant shall be responsible for
the cost of repairing such damage, subject to funding from any remaining unspent
portion of the Tenant Improvement Allowance.
EXHIBIT "B"
-8-
(f) Construction Services. Notwithstanding anything in the Lease or this
Work Letter Agreement to the contrary, during the construction of the Tenant
Improvements and during Tenant's installation of its furniture, fixtures and
equipment in (and move into) the Premises, Landlord shall provide, and neither
Tenant nor Tenant's Agents nor the Contractor shall be charged for any of the
following: (i) the use of the Building's loading docks and freight elevators;
(ii) HVAC service to the Premises; and/or (iii) electricity and/or water
provided to the Premises. In addition, Landlord shall provide parking in the
Exterior Areas of the Land for the Contractor and all of its subcontractors (and
each of their respective employees and agents) and for all of Tenant's Agents
free of charge.
(g) Definitions. All capitalized terms used in this Work Letter Agreement
shall have the same definition attributed to such terms herein as is attributed
to such terms in the Lease, unless such terms are otherwise defined herein.
IN WITNESS WHEREOF, the undersigned Landlord and Tenant have cause this Work
Letter Agreement to be duly executed by their duly authorized representatives as
of the date of the Lease.
LANDLORD: TENANT:
24000 DEVELOPMENT LLC, a Washington EMULEX DESIGN & MANUFACTURING
limited liability company CORPORATION, a Delaware corporation
By: _______________________________ By: __________________________________
Xxxxxxx Xxxxxxxxxx, Manager Print Name: ______________________
Print Title: _____________________
By: __________________________________
Print Name:_______________________
Print Title:______________________
EXHIBIT "B"
-8-
EXHIBIT "B-1"
WORK SCHEDULE
DATES MILESTONES
----- ----------
August 12, 2005 Architect delivers Space Plan to Landlord and Tenant
for their respective review and approval.
Three (3) business days Landlord and Tenant to complete its review of Space
after Tenant's delivery Plan and deliver written notice to (i) approving the
of Space Plans Space Plan or (ii) conditionally approving the Space
Plan and specifying required revisions to the Space
Plan.
August 26, 2005 Landlord shall cause the Permit Drawings to be
completed.
August 29, 2005 Landlord to cause Architect to submit drawing to City
of Bothell for permitting approval.
September 9, 2005 Landlord delivers (i) Working Drawings, (ii) an
initial draft of the construction contract for the
construction of the Tenant Improvements, and (iii) an
initial draft of the request for proposal from the
Bidding Contractors in connection with the
construction of the Tenant Improvements to Tenant for
Tenant's review and approval.
Three (3) business days Tenant to complete its review of Working Drawings
after Landlord's and deliver written notice to Landlord (i)
deliver of Working approving the Working Drawings or (ii) disapproving
Drawings the Working Drawings and specifying revisions to the
Working Drawings necessary to cause Tenant to approve
the Working Drawings.
September 23, 2005 Landlord to submit Working Drawings, Construction
Contract and Request for Proposal to Bidding
Contractors pursuant to Work Letter.
September 28, 2005 Landlord shall deliver to Tenant written
recommendation regarding the selection of one of the
Bidding Contractors.
Two (2) business days Tenant shall select one of the Bidding Contractors to
after Landlord's perform the Tenant Improvements.
delivery of Contractor
recommendation
Later of (i) two (2) Landlord to cause Contractor to commence the
calendar days after construction of the Tenant Improvements.
Tenant's selection of
Contractor to perform
Tenant Improvements, or
(ii) October 3, 2005
October 27, 2005 Obtain building permit from City of Bothell.
December 12, 2005 Landlord to cause Contractor to achieve Substantial
Completion.
EXHIBIT "B"
-10-
EXHIBIT "B-2"
INSURANCE REQUIREMENTS
1. GENERAL COVERAGES. All of Tenant's Agents shall carry worker's
compensation insurance covering all of their respective employees, and shall
also carry commercial general liability insurance, including property damage,
all with limits, in form and with companies as are required to be carried by
Tenant as set forth in Article 17 of the Lease.
2. SPECIAL COVERAGES. All of Tenant's Agents shall carry excess
liability and Products and Completed Operation Coverage insurance, each in
amounts not less than $1,000,000 per incident, $2,000,000 in aggregate, and in
form and with companies as are required to be carried by Tenant as set forth in
Article 17 of the Lease.
3. GENERAL TERMS. Certificates for all insurance carried pursuant to this
Exhibit "B-2" shall all be delivered to Landlord before any entry into the
Project by Tenant or any Tenant's Agent. All such policies of insurance must
contain a provision that the company writing said policy will give Landlord ten
(10) days prior notice of any cancellation, modification or lapse of the policy.
Tenant's Agents shall maintain all of the foregoing insurance coverage in force
until the Tenant Improvements are fully completed and accepted by Landlord. All
policies carried under this Exhibit "B-2" shall insure Landlord and Tenant, as
their interests may appear, as well as Contractor and Tenant's Agents. All
insurance maintained by Tenant's Agents shall preclude subrogation claims by the
insurer against anyone insured thereunder. Such insurance shall provide that it
is primary insurance as respects the Landlord and that any other insurance
maintained by Landlord is excess and noncontributing with the insurance required
hereunder. The requirements of the foregoing insurance shall not derogate from
the provisions for indemnification of
EXHIBIT "B"
-11-
EXHIBIT "C"
DEFINITION OF OPERATING EXPENSES, REAL PROPERTY
TAXES AND ASSESSMENTS, AND UTILITIES COSTS
1. ITEMS INCLUDED IN OPERATING EXPENSES. The term "Operating Expenses" as used
in the Lease to which this Exhibit "D" is attached means: all costs and expenses
of operation and maintenance of the Premises (as such terms are defined in the
Lease), other than "Real Property Taxes and Assessments" and "Utilities Costs"
as defined below, (which shall be separately accounted for), as determined by
standard accounting practices, which Landlord shall pay or become obligated to
pay because of or in connection with the ownership, management, maintenance,
repair, replacement, restoration or operation of the Premises and the personal
property of Landlord used in the operation of the Premises; provided, however,
"Operating Expenses" shall not include the cost of the acquisition of the
Premises or any of the items specifically set forth in Section 4 below.
Operating Expenses include, without limitation:
(a) costs of Landlord Insurance, and any insurance deductibles paid by Landlord;
(b) security and access control, waste disposal, window cleaning and janitorial
services for the Premises, to the extent not separately reimbursed to Landlord;
(c) wages, salaries of all persons (other than executive personnel) to the
extent engaged in the operation, maintenance or access control of the Premises,
including all taxes, insurance, and benefits relating thereto (if any such
person perform services to more than one property, then the items in this
subsection (c) for such person shall be allocated proportionately among the
properties served);
(d) a market rate management/administrative fee not to exceed three percent
(3%), and not less than one percent (1%), of the annual gross revenues of the
Building exclusive of the proceeds of financing or a sale of the Building;
(e) supplies, materials, equipment and tools including rental of personal
property used for maintenance;
(f) repair and maintenance (including maintenance, service and repair
agreements) of the elevators and the structural portions of the Building,
including the plumbing, heating, ventilating, air-conditioning and electrical
systems installed or furnished by Landlord, but excluding any Building defects
that existed as of the Commencement Date or repair and maintenance expenses
arising due to Landlord's failure to repair and maintain the Premises, the
Building and the Exterior Areas in accordance with the Lease and Exhibit "D"
attached thereto;
(g) maintenance, cleaning, sweeping, restriping, resurfacing, ice and snow
removal, directional signs, markers, car stops, and other costs and upkeep of
all Parking Areas and Exterior Areas;
(h) depreciation on a straight line basis and rental of personal property used
in maintenance of the Exterior Areas;
(i) amortization on a straight line basis over the useful life of all
capitalized expenditures which are: (i) reasonably intended to produce a
reduction in operating charges or energy consumption provided that Tenant has
approved such capital expenditure in writing in Tenant's reasonable discretion;
or (ii) required under any governmental law or regulation that was not
applicable to the Building as of the Commencement Date; or (iii) for replacement
of any Building equipment needed to operate the Building at the same quality
levels as prior to the replacement;
XXXXXXX "X"
-0-
(x) costs and expenses of gardening and landscaping; and
(k) maintenance of Tenant's signage.
2. REAL PROPERTY TAXES AND ASSESSMENTS. The term "Real Property Taxes and
Assessments", as used in this Exhibit "C", means: real property taxes and
assessments imposed on the Premises by any governmental authority having the
direct power to tax. When calculating Real Property Taxes and Assessments for
purposes of establishing Tenant's Expense Allowance, Real Property Taxes and
Assessments shall not include penalties and other delinquency charges resulting
from the late payment thereof (unless such late payment is due to Tenant's
failure to pay additional rent on time).
3. UTILITIES COSTS. As used in this Lease, "Utilities Costs" shall mean all
charges for utilities for the Premises including but not limited to water,
sewer, electricity, natural gas, telephone, and cable, the costs of heating,
ventilating and air conditioning and other utilities.
4. ITEMS EXCLUDED FROM OPERATING EXPENSES, REAL PROPERTY TAXES AND ASSESSMENTS,
AND UTILITIES COSTS. Notwithstanding the provisions of Paragraphs 1, 2 and 3
above to the contrary, as applicable, "Operating Expenses," Real Property Taxes
and Assessments," and "Utilities Costs" will not include:
(a) Landlord's federal or state income, franchise, inheritance or estate taxes;
(b) any ground lease rental;
(c) costs incurred by Landlord for the repair of damage to the Building to the
extent that Landlord is reimbursed (or entitled to reimbursement) by insurance
or condemnation proceeds or by prior tenants, owners, warrantors or other third
persons;
(d) depreciation, amortization and interest payments, except as specifically
provided herein, and except on materials, tools, supplies and vendor-type
equipment purchased by Landlord to enable Landlord to supply services Landlord
might otherwise contract for with a third party, where such depreciation,
amortization and interest payments would otherwise have been included in the
charge for such third party's services and such election to purchase does not
result in increased operating expenses as compared to independent third party
charges, all as determined in accordance with standard accounting practices;
(e) brokerage commissions, finders' fees, attorneys' fees, space planning costs,
marketing costs and other costs incurred by Landlord in leasing or attempting to
lease space in the Building;
(f) costs of a capital nature, including, without limitation, capital
improvements and capital replacements, all as determined in accordance with
standard accounting practices; provided, however, the capital expenditures set
forth in Section 1(i) of this Exhibit "C" will in any event be included in the
definition of Operating Expenses;
(g) interest, principal, points and fees on debt or amortization on any
mortgage, deed of trust or other debt encumbering the Building;
(h) accounting and attorneys' fees and other costs and expenses incurred in
connection with negotiations or disputes with owners and past or prospective
tenants or other occupants of the Building;
(i) except for the administrative/management fees described in Section 1(e) of
this Exhibit "C", costs of Landlord's general corporate overhead;
EXHIBIT "C"
-2-
(j) all items and services for which Tenant reimburses Landlord (other than
through Section 6 of the Lease) or otherwise pays directly;
(k) costs arising from Landlord's charitable or political contributions.
(l) any bad debt loss or expenses, rent loss, or reserves for bad debt or rent
loss;
(m) costs associated with the operation of the business of the partnership or
entity which constitutes Landlord as the same are distinguished from the costs
of operation of the Building and the Exterior Area, including partnership
accounting and legal matters, costs of defending any lawsuits with any mortgagee
(except as the actions of Tenant may be in issue), costs of selling,
syndicating, financing, mortgaging or hypothecating any of Landlord's interest
in the Land or the Building, costs incurred in connection with any disputes
between Landlord and its employees, or between Landlord and Building management,
or between Building management and its employees;
(n) salaries and other benefits paid to the employees of Landlord (except as
provided in 1(c) above);
(o) overhead and profit increment paid to Landlord or to subsidiaries or
affiliates of Landlord for goods and/or services in the Building to the extent
the same exceeds the costs of such goods and/or services rendered by similarly
qualified unaffiliated third parties with respect to similar projects on a
competitive basis;
(p) costs of acquiring or leasing sculptures, paintings, or other objects of
art;
(q) any costs expressly excluded from Operating Expenses elsewhere in the Lease;
(r) amount of rent for any office space occupied by Building management
personnel;
(s) costs necessitated by or resulting from the negligence or willful misconduct
of Landlord or any of its respective agents, employees, vendors or contractors,
or providers of materials or services, including but not limited to penalties,
fines, judgments or awards;
(t) costs arising from Landlord's failure to perform repair and maintenance to
the Building, the premises or the Exterior Areas in accordance with the Lease
and Exhibit "D" attached to the Lease, but only to the extent that such costs
are in addition to costs that would normally have been incurred;
(u) costs arising from the testing for, remediation of, or otherwise relating in
any manner to, Hazardous Materials;
(v) any flowers, gifts, balloons and the like provided to any entity whatsoever;
(w) the costs of any magazine, newspaper, trade or other subscriptions or
Landlord's professional association dues;
(x) costs of installing, maintaining and operating any specialty service
operated by Landlord (including without limitation, any luncheon club,
broadcasting facility, sundry shop, restaurant or cafeteria, retail store, or
other recreational facility);
(y) costs of insurance maintained by Landlord other than Landlord's Insurance
pursuant to Section 17(e) of the Lease;
XXXXXXX "X"
-0-
(x) any entertainment or dining provided to vendors to increase service or lower
Operating Expenses, or travel expenses for any purpose;
(aa) costs incurred as a result of Landlord's negligence, inability or
unwillingness to make payments of, and/or to file any tax or informational
returns with respect to, any taxes, when due;
(bb) all assessments which are not specifically charged to Tenant because of
what Tenant has done, which can be paid by Landlord in installments, shall be
paid by Landlord in a commercially reasonable number of installments and not
included as Operating Expenses except in the year in which the assessment or
premium installment is actually paid;
(cc) except while making repairs or as needed on an emergency basis, rentals and
other related expenses incurred in leasing air conditioning systems, elevators
or other equipment which, if purchased, the costs of which would be excluded
from Operating Expenses as a capital expenditure or which equipment would
otherwise be excluded from the definition of Operating Expenses;
(dd) any costs or expenses relating to new development or a material change of
use on or about the Land, including any costs to satisfy entitlement or
development conditions or other agreements relating to the development,
entitlement, construction or financing of the Land;
(ee) costs of correcting any structural defects in the Building;
(ff) cost of correcting any violations of Laws existing as of the Commencement
Date;
(gg) any expenses for repairs or maintenance which are covered by warranties,
guarantees or service contracts (excluding any mandatory deductibles);
(hh) any of the following items incurred by Landlord: (1) income tax, excess
profits or revenue tax, excise tax or inheritance tax, gift tax, franchise tax,
corporation tax, capital levy transfer, estate, succession or other similar tax
or charge that may be payable by or chargeable to Landlord under any present
Laws; (2) interest or penalties imposed upon Landlord for late payment of real
estate taxes, except as provided in 2 above; and (3) real estate taxes resulting
from the expansion of the Building or the Exterior Areas or the construction of
new buildings or improvements on the Land, other than the Tenant Improvements
and Alterations; and
(ii) the Tenant Improvement Costs as described in the Work Letter.
EXHIBIT "C"
-4-
EXHIBIT "D"
STANDARDS FOR SERVICES
The following standards for and services are in effect. Landlord reserves the
right to adopt nondiscriminatory modifications and additions hereto.
Subject to the terms and conditions of the Lease and provided Tenant remains in
occupancy of the Premises, Landlord will provide or make available the following
services:
1. Landlord shall keep the elevator in good condition and repair, and shall
perform repair and maintenance to the elevator and appurtenant systems
consistent with practices for similar buildings in the Comparison Market area.
2. Landlord shall keep the Building's HVAC units, ducts and related systems
(collectively, the "HVAC System") in good condition and repair, and further
shall enter into an HVAC preventative maintenance contract that provides for
regular inspections and maintenance of the HVAC System in accordance with
industry standards.
3. Landlord shall keep and maintain the Exterior Areas (including the Parking
Areas) in good condition and repair, in a manner consistent with similar office
buildings in the Comparison Market.
4. Landlord shall provide janitorial services to the Premises Monday through
Friday, except for Federal or Washington State holidays, in accordance with the
minimum specifications set forth in Schedule "D-1" attached hereto.
5. Subject to Landlord's prior approval of the plans and specifications
therefor, which approval shall not be unreasonably withheld, conditioned or
delayed, Tenant shall have the right, at Tenant's sole cost and expense, to
install and maintain a security system within the Premises, so long as such
system is compatible with the Building Fire Life Safety System; provided that at
Tenant's option, such security system may be installed as a part of the Tenant
Improvements and paid for in the manner provided under the Lease of which this
Exhibit is a part for payment of the costs of the Tenant Improvements. Tenant
shall provide Landlord with access cards, or other access through the security
system to the Building.
6. Landlord shall not decrease in any respect the level or quality of services
provided to the Premises during the Term.
SCHEDULE "D-1"
-1-
SCHEDULE "D-1"
JANITORIAL SPECIFICATIONS
CLEANING SPECIFICATIONS
A. Corridors and Entries
Daily Services
1 Sweep and clean building entrances.
2. Building telephones will be cleaned and sanitized.
3. Clean and remove smudges from entry door glass.
4. Clean all entry handles, door plates and metal trim.
5. Wipe clean all glass, wood or metal doors and door jams.
6. Screen and sand urns of butts and debris. Clean container and add
sand as needed.
7. Empty all trash receptacles and replace plastic liner where
necessary.
8. Remove all debris from landscaped pots and planters.
9. Dust and clean all horizontal surfaces under seven feet.
10. Dust mop, damp mop or buff tile floors.
11. Clean and remove smudges and marks on painted walls, where possible
without removing the paint, wall coverings and enclosed art work.
12. Clean and sanitize all water fountains.
13. Wipe clean all directory boards.
14. Wipe clean all fire extinguisher cabinets and glass
15. Spot clean all elevator doors and call plates.
16. Dust and clean all lobby and corridor signage.
Weekly Services
1. Clean and polish all entry metal and xxxxx.
2. Dust all ledges.
3. Dust and clean or polish all lobby baseboards.
Monthly Services
1. Dust high ceiling corners and entry ways.
2. Dust and clean or polish all hallway baseboards.
Quarterly Services
1. Clean all ceiling vents and grills.
2. Strip, reseal or refinish common area floors as necessary.
B. General Offices and Workstations
Daily Services Unless Otherwise Stated
1. Remove hand spots or smudges from entry doors.
2. Dust and/or damp mop all non-carpeted areas.
3. Vacuum traffic areas and general office space.
4. Properly position furniture in conference rooms.
5. Remove fingerprints and smudges from all walls, partitions, desks,
cabinets and doors, light switch covers and doorknob handles twice a
week.
6. Empty all wastebaskets and carry trash to designated areas for
removal. Replace plastic liners as needed.
7. Clean and wash all lunchroom table tops and counter cabinets.
Weekly Services Unless Otherwise Stated
1. Thoroughly vacuum entire carpet areas. Remove staples and other
debris. Two times a week.
2. Dust all ledges, files baseboards and xxxxx under 7 feet monthly.
Monthly Services Unless Otherwise Stated
1. Dust all ledges, moldings, picture shelves, etc. over 7 feet.
2. Brush down and clean all vents and grills.
SCHEDULE "D-1"
-1-
3. Strip, clean and apply floor dressing to all composition floors
yearly.
4. Scrub and refinish all tile floors quarterly.
C. Restrooms
Daily Services
1. Clean and damp-mop floors.
2. Dust, clean and wash where necessary all partitions, tile walls,
dispensers, and receptacles.
3. Clean underside rims of urinals, toilet bowls nightly, removing
scale and stains, wash both sides of toilet seats with soap and
water disinfectant.
4. Empty, clean, sanitize and polish all paper dispensers, replacing
liners as necessary.
5. Clean all mirrors.
6. Damp wipe all chrome, metal fixtures, hand plates, kick plates,
utility covers, plumbing, clean out covers and door knobs.
7. Spot clean with disinfectant all partitions and tile walls.
8. Fill all dispensers with soap, towels, toilet paper and sanitary
napkins.
9. Report all burned out lights, leaking faucets, running plumbing or
other maintenance needs.
10. Janitor carts will not be brought into restroom areas or used to
prop open doors. Carts can be parked outside the restroom doors.
11. Restroom doors will be propped open with a rubber stop and sign
indicating restroom closed for cleaning, placed outside.
Weekly Services
1. Wash all waste containers and disinfect.
2. Clean and polish all doors, door plates and hardware.
3. Wash down partitions inside and out and disinfect.
Monthly Services
1. Detail all toilet compartments and fixtures.
2. Brush and clean all grills and vents.
3. Dust ledges and base boards every other month.
Yearly Services
1. Strip and apply new finish to tile floors.
SCHEDULE "D-1"
-2-
EXHIBIT "E"
SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT
RECORDING REQUESTED BY AND
WHEN RECORDED MAIL TO:
____________________________
____________________________
____________________________
Attention:__________________
____________________________
________________________________________________________________________________
(Space Above This Line For Recorder's Use Only)
SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT
THIS SUBORDINATION, NON-DISTURBANCE AND ATTORNMENT AGREEMENT (this
"Agreement"), is made and entered into as of the ___ day of ___________, 200_,
by and among EMULEX DESIGN & MANUFACTURING CORPORATION, a Delaware corporation
("Tenant"), whose address is 0000 Xxxxx Xxxxxx, Xxxxx Xxxx, Xxxxxxxxxx 00000,
Attention: EVP HR & Facilities and General Counsel, 24000 Development LLC, a
Washington limited liability company ("Landlord"), whose address is
________________________________________________, and _________________, a
________ ("Lender"), whose address is _____________________.
A. Lender has agreed to make a mortgage loan (the "Loan") to
Landlord secured by a deed of trust (the "Deed of Trust") on Landlord's interest
in the real property legally described in Exhibit "A" attached hereto (the
"Premises")
B. Tenant is the present lessee under that certain lease, dated as
of August __, 2005, made by and between Tenant, as Tenant, and Landlord, as
Landlord, demising a portion of the Premises and other property (said lease as
so amended being referred to as the "Lease"); and
C. Subject to the terms and conditions of this Agreement, Tenant has
agreed to subordinate its interest in the Lease to the lien of the Deed of Trust
so long as, among other things, Lender agrees not to disturb Tenant's possession
of the portion of the Premises covered by the Lease (the "Demised Premises").
NOW, THEREFORE, the parties hereby agree as follows:
1. Subordination. Subject to the terms and conditions hereinafter
set forth, the Lease, and the rights of Tenant in, to and under the Lease and
the Demised Premises, are hereby subjected and subordinated to the lien of the
Deed of Trust, and to any renewal, substitution, extension, modification or
replacement thereof.
EXHIBIT "E"
-1-
2. Tenant Not To Be Disturbed. So long as Tenant is not in default
(beyond any period given Tenant by the terms of the Lease to cure such default)
in the payment of rent or additional rent or performance of any of the terms,
covenants or conditions of the Lease on Tenant's part to be performed, (a)
Tenant's possession of the Demised Premises, and its rights and privileges under
the Lease shall not be diminished or interfered with by Lender, and (b) Lender
will not join Tenant as a party defendant in any action or proceeding
foreclosing the Deed of Trust unless such joinder is necessary to foreclose such
Deed of Trust and then only for such purpose and not for the purpose of
terminating the Lease. Lender represents and warrants that it has received and
reviewed a copy of the Lease.
3. Tenant to Attorn To Lender. If the Premises shall be sold by
reason of foreclosure (whether judicial or non judicial) or other proceedings
brought to enforce the Deed of Trust, or the Premises shall be transferred by
deed in lieu of foreclosure, the Lease shall continue in full force and effect
as a direct lease between the then owner of the Premises, who shall succeed to
the rights and duties of the Landlord, and Tenant for the balance of the term
thereof. Tenant shall attorn to Lender or any other such owner as its Landlord,
said attornment to be effective and self operative without the execution of
further instruments; provided, however, that Lender or any such other owner
shall not be (a) personally liable for any act or omission of Landlord or any
prior landlord which cannot be cured; (b) subject to any offsets or defenses
which Tenant might have against Landlord or any prior landlord except to the
extent of Tenant's right to offsets set forth in the Lease; (c) required or
obligated to credit Tenant with any rent or additional rent for any rental
period beyond the then current month which Tenant might have paid Landlord or
any prior landlord, excluding any reconciliations as provided for in the Lease;
or (d) liable for the return of any security deposit unless and only to the
extent such security deposit shall have been actually received by Lender. Tenant
hereby agrees that upon the occurrence of any default under the Loan or the
documents evidencing or securing the same, and in the event of a demand on
Tenant by Lender, or its successors and assigns, for the payment to Lender or
its successors and assigns of the rent due under the Lease, Tenant will pay said
rent to Lender and Landlord hereby consents to said payment and releases Tenant
from any and all liability, damages, or claims in connection with any such
payment or payments. Landlord agrees that receipt by Tenant of any such demand
shall be conclusive evidence of the right of Lender to the receipt of said
rental payments. Tenant shall be under no obligation to pay rent to Lender or
any such other owner until Tenant receives written notice from Lender or any
such other owner.
4. Notice of Default. If Landlord is in material default of one or
more of its obligations under the Lease, Tenant agrees to give written notice
thereof to Lender. Tenant further agrees that Lender shall have the right, but
not the obligation, to cure such default within thirty (30) days or if such
default cannot be cured within that time, then such additional time as may be
reasonably required to complete such cure, provided, that Lender commences such
cure during the initial thirty (30) day period and thereafter diligently
prosecutes such cure to completion.
5. Notice of Discharge. Landlord shall give notice to Tenant of the
reconveyance or other release of the Deed of Trust within thirty (30) days after
the date the reconveyance or other release is recorded.
6. Limitation. This Agreement shall not apply to any equipment,
inventory, merchandise, furniture, fixtures or other personal property owned or
leased by Tenant which is now or hereafter placed or installed on the Demised
Premises, and Tenant shall have the full right to remove said property at any
time during or at the expiration of the Lease term.
7. Notices. Any notice required or permitted to be given hereunder
must be in writing and may be given by personal delivery (including delivery by
overnight courier or an
EXHIBIT "E"
-2-
express mailing service) or by mail, if sent by registered or certified mail, to
the parties at their addresses set forth above. The addresses to which notices
shall be sent may be changed by any party by notice given pursuant to this
paragraph.
8. Successors And Assigns. This Agreement and each and every
covenant, agreement and other provision hereof shall be binding upon and shall
inure to the benefit of the parties hereto and their representatives, successors
and assigns.
9. Miscellaneous. This Agreement may not be modified other than by
an agreement in writing, signed by the parties hereto or by their respective
successors in interest. Nothing in this Agreement shall in any way impair or
affect the lien created by the Deed of Trust or the other lien rights of Lender.
10. Counterparts. This Agreement may be executed in counterparts
which together shall constitute but one and the same original.
[balance of this page left blank; signature page follows]
EXHIBIT "E"
-3-
IN WITNESS WHEREOF, the parties hereto have each caused this
Subordination, Non-Disturbance and Attornment Agreement to be executed as of the
date first above written.
"Lender"
________________________________________
Its:
"Landlord"
24000 Development LLC, a Washington
limited liability company
By: ____________________________________
Xxxxxxx Xxxxxxxxxx, Manager
"Tenant"
EMULEX DESIGN & MANUFACTURING
CORPORATION, a Delaware corporation
By:
By: ____________________________________
Name: __________________________________
Its: ___________________________________
[NOTARY BLOCKS TO BE ATTACHED PRIOR TO EXECUTION]
EXHIBIT "E"
-4-
EXHIBIT A
LEGAL DESCRIPTION OF PREMISES
Lot 6, QUADRANT XXXXX XXXXX CENTER, according to the Plat thereof recorded
in Volume 54 of Plats, Pages 165 through 169, inclusive, in Snohomish County,
Washington.
EXHIBIT "A" TO
EXHIBIT "E"
-5-
EXHIBIT "F-1"
TENANT ESTOPPEL CERTIFICATE
The undersigned, __________________________________________________ ("Tenant"),
hereby certifies to _______________________________________________________, as
follows:
1. Attached hereto is a true, correct and complete copy of that certain lease
dated _____________________, between _____________________________, a __________
_________________________________ ("Landlord") and Tenant (the "Lease"),
regarding the premises located at ______________________________________________
________________________________ (the "Premises"). The Lease is now in full
force and effect and has not been amended, modified or supplemented,
except as set forth in Section 4 below.
2. The Term of the Lease commenced on __________________, __.
3. The Term of the Lease will expire on _________________________, __.
4. The Lease has: (Initial one)
( ) not been amended, modified, supplemented, extended, renewed or
assigned.
( ) been amended, modified, supplemented, extended, renewed or
assigned by the following described terms or agreements, copies of which are
attached hereto:
________________________________________________________________________________
_______________________________________________________________________________.
5. Tenant has accepted and is now in possession of the Premises.
6. Tenant and Landlord acknowledge that Landlord's interest in the Lease will be
assigned to ________________________________and that no modification,
adjustment, revision or cancellation of the Lease or amendments thereto shall be
effective unless written notice is given to ___________________________________,
and that until further notice, payments under the Lease may continue as
heretofore.
7. The amount of Monthly Base Rent is $__________________________________.
8. The amount of Security Deposit (if any) is $__________________________. No
other security deposits have been made except as follows: ____________________
______________________________________________________________________________.
9. Tenant is paying the full lease rental which has been paid in full as of the
date hereof. No rent or other charges under the Lease have been paid for more
than thirty (30) days in advance of its due date except as follows: __________
______________________________________________________________________________.
10. All work required to be performed by Landlord under the Lease has been
completed except as follows: _________________________________________________.
11. To the actual knowledge of Tenant, There are no Defaults on the part of the
Landlord under the Lease except as follows: __________________________________
______________________________________________________________________________.
EXHIBIT "F-1"
-1-
12. To the actual knowledge of Tenant, Tenant has NO defense as to its
obligations under the Lease and claims no set-off or counterclaim against the
other party except as follows: _________________________________________________
________________________________________________________________________.
13. Tenant has no right to any concession (rental or otherwise) or similar
compensation in connection with renting the space it occupies other than as
provided in the Lease except as follows: _______________________________________
___________________________________________________________.
14. All provisions of the Lease and the amendments thereto (if any) referred to
above are hereby ratified.
The foregoing certification is made with the knowledge that ____________________
is relying upon the representations herein made in funding a loan to Landlord in
purchasing the Premises.
IN WITNESS WHEREOF, this certificate has been duly executed and delivered by the
authorized officers of the undersigned as of ___________________________, 2____.
TENANT:
________________________________________
a_______________________________________
By: ____________________________________ SAMPLE ONLY
Print Name: ________________________ [NOT FOR EXECUTION]
Print Title: _______________________
By: ____________________________________
Print Name: ________________________
Print Title: _______________________
EXHIBIT "F-1"
-2-
EXHIBIT "F-2"
LANDLORD ESTOPPEL CERTIFICATE
The undersigned, __________________________________________________("Landlord"),
hereby certifies to , as
follows:
1. Attached hereto is a true, correct and complete copy of that certain lease
dated _____________________, between ____________________________, a ___________
("Landlord") and Tenant (the "Lease"), regarding the premises located at
________________________________________________________________________________
(the "Premises"). The Lease is now in full force and effect and has not been
amended, modified or supplemented, except as set forth in Section 4 below.
2. The Term of the Lease commenced on ________________ , __.
3. The Term of the Lease will expire on ________________ , __.
4. The Lease has: (Initial one)
( ) not been amended, modified, supplemented, extended, renewed or
assigned.
( ) been amended, modified, supplemented, extended, renewed or
assigned by the following described terms or agreements, copies of which are
attached hereto: ______________________________________________________________.
5. The amount of Monthly Base Rent under the Lease is $________________________.
6. The amount of Security Deposit (if any) is $__________________________. No
other security deposits have been made except as follows:_______________________
_____________________________________________________________________________.
7. Tenant is paying the full lease rental which has been paid in full as of the
date hereof. No rent or other charges under the Lease have been paid for more
than thirty (30) days in advance of its due date except as follows: ____________
______________________________________________________________________________.
8. Except for defaults that have been fully cured by Tenant, Landlord has not
delivered written notice of any default under the Lease to Tenant, except as
follows:________________________________________________________________________
___________________________________________________________________ .
9. To Landlord's actual knowledge, without investigation or inquiry, Tenant is
not in default under the Lease and no conditions exist which, with the giving of
notice or the passage of time, would constitute a Default by Tenant under the
Lease, except as follows:_______________________________________________________
_______________________________________________________________________________.
EXHIBIT "F-2"
-1-
IN WITNESS WHEREOF, this certificate has been duly executed and delivered by the
authorized officers of the undersigned as of ___________________________, 2____.
LANDLORD:
________________________________________
a_______________________________________
By: ____________________________________ SAMPLE ONLY
Print Name:_________________________ [NOT FOR EXECUTION]
Print Title:________________________
EXHIBIT "F-2"
-2-
