Dated 5 July 2010 ALPHA ELEPHANT INC as Borrower the financial institutions listed in Schedule 1 as Original Lenders arranged by DEUTSCHE BANK AG, LONDON BRANCH with DEUTSCHE BANK LUXEMBOURG S.A. as Agent DEUTSCHE BANK LUXEMBOURG S.A. as Security...
Clause | Page | |||
SECTION 1 — INTERPRETATION |
1 | |||
1 Definitions and interpretation |
1 | |||
SECTION 2 — THE FACILITY |
21 | |||
2 The Facility |
21 | |||
3 Purpose |
21 | |||
4 Conditions of Utilisation |
22 | |||
SECTION 3 — UTILISATION |
23 | |||
5 Utilisation |
23 | |||
SECTION 4 — REPAYMENT, PREPAYMENT AND CANCELLATION |
24 | |||
6 Repayment |
24 | |||
7 Illegality, prepayment and cancellation |
24 | |||
SECTION 5 — COSTS OF UTILISATION |
29 | |||
8 Interest |
29 | |||
9 Interest Periods |
29 | |||
10 Break Costs |
30 | |||
11 Fees |
30 | |||
SECTION 6 — ADDITIONAL PAYMENT OBLIGATIONS |
31 | |||
12 Tax gross-up and indemnities |
31 | |||
13 Increased Costs |
35 | |||
14 Other indemnities |
36 | |||
15 Mitigation by the Lenders |
39 | |||
16 Costs and expenses |
39 | |||
SECTION 7 — GUARANTEE |
41 | |||
17 Guarantee and indemnity |
41 | |||
SECTION 8 — REPRESENTATIONS, UNDERTAKINGS AND EVENTS OF DEFAULT |
45 | |||
18 Representations |
45 | |||
19 Information undertakings |
52 | |||
20 General undertakings |
56 |
Clause | Page | |||
21 Dealings with Ship |
58 | |||
22 Condition and operation of Ship |
61 | |||
23 Insurance |
65 | |||
24 Valuations |
70 | |||
25 Bank accounts |
72 | |||
26 Business restrictions |
74 | |||
27 Events of Default |
78 | |||
SECTION 9 — CHANGES TO PARTIES |
84 | |||
28 Changes to the Lenders |
84 | |||
29 Changes to the Obligors |
87 | |||
SECTION 10 — THE FINANCE PARTIES |
88 | |||
30 Roles of Agent, Security Agent and the Arranger |
88 | |||
31 Conduct of business by the Finance Parties |
104 | |||
32 Sharing among the Finance Parties |
106 | |||
SECTION 11 — ADMINISTRATION |
108 | |||
33 Payment mechanics |
108 | |||
34 Set-off |
111 | |||
35 Notices |
111 | |||
36 Calculations and certificates |
113 | |||
37 Partial invalidity |
113 | |||
38 Remedies and waivers |
113 | |||
39 Amendments and grant of waivers |
114 | |||
40 Counterparts |
115 | |||
41 Confidentiality |
115 | |||
SECTION 12 — GOVERNING LAW AND ENFORCEMENT |
118 | |||
42 Governing law |
118 | |||
43 Enforcement |
118 |
Clause | Page | |||
Schedule 1 The original parties |
119 | |||
Schedule 2 Ship information |
123 | |||
Schedule 3 Conditions precedent |
124 | |||
Schedule 4 Utilisation Request |
130 | |||
Schedule 5 Form of Transfer Certificate |
131 | |||
Schedule 6 Approved Technical Managers |
133 | |||
Schedule 7 Form of Technical Management Agreement |
134 |
(1) | ALPHA ELEPHANT INC (the Borrower); |
|
(2) | SOLAR VLCC CORPORATION (the Parent); |
|
(3) | DEUTSCHE BANK AG, LONDON BRANCH as mandated lead arranger (the Arranger); |
|
(4) | THE FINANCIAL INSTITUTIONS listed in Schedule 1 as lenders (the Original Lenders); |
|
(5) | DEUTSCHE BANK LUXEMBOURG S.A. as agent for the other Finance Parties (the Agent); and |
|
(6) | DEUTSCHE BANK LUXEMBOURG S.A. as security agent for the Finance Parties (the Security Agent). |
1 | Definitions and interpretation |
|
1.1 | Definitions |
1
2
(a) | the interest which a Lender should have received for the period from the date of
receipt of all or any part of its participation in the Loan or Unpaid Sum to the last
day of the current Interest Period in respect of the Loan or Unpaid Sum, had the
principal amount or Unpaid Sum received been paid on the last day of that Interest
Period; |
(b) | the amount which that Lender would be able to obtain by placing an amount equal
to the principal amount or Unpaid Sum received by it on deposit with a leading bank in
the Interbank Market for a period starting on the Business Day following receipt or
recovery and ending on the last day of the current Interest Period. |
3
(a) | in relation to an Original Lender, the amount set opposite its name under the
heading “Commitment” in Schedule 1 (The original parties) and the amount of any other
Commitment transferred to it under this Agreement; and |
(b) | in relation to any other Lender, the amount of any Commitment transferred to it
under this Agreement, |
(a) | any member of the Group or any of its advisers; or |
4
(b) | another Finance Party, if the information was obtained by that Finance Party
directly or indirectly from any member of the Group or any of its advisers, |
(i) | is or becomes public information other than as a direct or indirect
result of any breach by that Finance Party of clause 41 (Confidentiality); or |
(ii) | is identified in writing at the time of delivery as non-confidential
by any member of the Group or any of its advisers; or |
(iii) | is known by that Finance Party before the date the information is
disclosed to it in accordance with paragraphs (a) or (b) above or is lawfully
obtained by that Finance Party after that date, from a source which is, as far as
that Finance Party is aware, unconnected with the Group and which, in either case,
as far as that Finance Party is aware, has not been obtained in breach of, and is
not otherwise subject to, any obligation of confidentiality; or |
(iv) | any Obligor is required to provide to a Finance Party under the
Finance Documents whether upon request or otherwise. |
5
(a) | enforcement, clean-up, removal or other governmental or regulatory action or
orders or claims instituted or made pursuant to any Environmental Laws or resulting from
a Spill; or |
||
(b) | any claim made by any other person relating to a Spill. |
(a) | any Fleet Vessel or its owner, operator or manager may be liable for
Environmental Claims arising from the Spill (other than Environmental Claims arising and
fully satisfied before the date of this Agreement); and/or |
(b) | any Fleet Vessel may be arrested or attached in connection with any such
Environmental Claim. |
6
(a) | moneys borrowed; |
(b) | any amount raised by acceptance under any acceptance credit facility or
dematerialised equivalent; |
(c) | any amount raised pursuant to any note purchase facility or the issue of bonds,
notes, debentures, loan stock or any similar instrument; |
(d) | the amount of any liability in respect of any lease or hire purchase contract
which would, in accordance with GAAP, be treated as a finance or capital lease; |
(e) | receivables sold or discounted (other than any receivables to the extent they are
sold on a non-recourse basis); |
(f) | any Treasury Transaction (and, when calculating the value of that Treasury
Transaction, only the marked to market value shall be taken into account); |
(g) | any counter-indemnity obligation in respect of a guarantee, bond, standby or
documentary letter of credit or any other instrument issued by a bank or financial
institution; |
7
(h) | any amount of any liability under an advance or deferred purchase agreement if
(a) one of the primary reasons behind entering into the agreement is to raise finance or
(b) the agreement is in respect of the supply of assets or services and payment is due
more than 180 days after the date of supply; |
(i) | any amount raised under any other transaction (including any forward sale or
purchase agreement) having the commercial effect of a borrowing; and |
(j) | the amount of any liability in respect of any guarantee for any of the items
referred to in paragraphs (a) to (i) above. |
(a) | each Finance Party and each Receiver and any attorney, agent or other person
appointed by them under the Finance Documents; |
||
(b) | each Affiliate of those persons; and |
(c) | any officers, employees or agents of any of the above persons. |
8
(a) | all policies and contracts of insurance; and |
(b) | all entries in a protection and indemnity or war risks or other mutual insurance
association, |
(a) | the principle that equitable remedies may be granted or refused at the discretion
of a court and the limitation of enforcement by laws relating to insolvency,
reorganisation and other laws generally affecting the rights of creditors; |
(b) | the time barring of claims under the Limitation Acts, the possibility that an
undertaking to assume liability for, or indemnify a person against, non-payment of UK
stamp duty may be void and defences of set-off or counterclaim; and |
(c) | similar principles, rights and defences under the laws of any Relevant
Jurisdiction. |
(a) | any Original Lender; and |
(b) | any bank, financial institution, trust, fund or other entity which has become a
Party in accordance with clause 28 (Changes to the Lenders), |
9
(a) | the business, operations, property, condition (financial or otherwise) or
prospects of the Group taken as a whole; or |
(b) | the ability of an Obligor to perform its obligations under the Finance Documents;
or |
(c) | the validity or enforceability of, or the effectiveness or ranking of any
Security Interest granted or purporting to be granted pursuant to any of, the Finance
Documents or the rights or remedies of any Finance Party under any of the Finance
Documents. |
10
(a) | the Mortgage; |
||
(b) | the General Assignment; |
||
(c) | the Share Security; |
||
(d) | the Account Security; |
||
(e) | the Co-ordination Agreement; |
||
(f) | any Manager’s Undertaking if required under clause 21.7 (Manager); and |
||
(g) | the Beta Security Documents. |
(a) | unless a Default is continuing, any ship repairer’s or outfitter’s possessory
lien in respect of the Ship for an amount not (except with the prior written consent of
the Majority Lenders) exceeding the Major Casualty Amount; |
(b) | any lien on the Ship for master’s, officer’s or crew’s wages outstanding in the
ordinary course of its trading; |
(c) | any lien on the Ship for salvage; and |
11
(d) | liens arising in the ordinary course of trading by statute or by operation of law
in respect of obligations, having a quantum of no more than $1,500,000 in aggregate at
any time, which are not overdue or which are being contested in good faith by
appropriate proceedings (and for the payment of which adequate reserves have been
provided) so long as any such proceedings or the continued existence of such lien do not
involve any likelihood of the sale, forfeiture or loss of, or of any interest in, the
Ship. |
(a) | granted by the Finance Documents; or |
||
(b) | a Permitted Maritime Lien; or |
(c) | is approved by the Majority Lenders (whether by the Co-ordination Agreement or
otherwise). |
(d) | any other lien arising by operation of law or otherwise in the ordinary course of
the operation, repair or maintenance of that Ship, provided such liens do not secure
amounts more than 30 days overdue (unless the overdue amount is being contested in good
faith by appropriate steps with a reserve of such overdue amount having been established
in a blocked account which has been charged to the Security Agent) and subject, in the
case of liens for repair or maintenance, to clause 22.15 (Repairer’s liens). |
(a) | its jurisdiction of incorporation; |
||
(b) | any jurisdiction where any Charged Property owned by it is situated; |
(c) | any jurisdiction where it conducts its business; and |
12
(d) | any jurisdiction whose laws govern the perfection of any of the Security
Documents entered into by it. |
(a) | the Original Security Documents; |
(b) | any other document as may be executed to guarantee and/or secure any amounts
owing to the Finance Parties under this Agreement or any other Finance Document. |
13
(a) | directly or indirectly controlled by such person; or |
||
(b) | of whose dividends or distributions on ordinary voting share capital such person
is entitled to receive more than 50 per cent. |
(a) | actual, constructive, compromised or arranged total loss; or |
||
(b) | requisition for title, confiscation or other compulsory acquisition by a
government entity; or |
||
(c) | hijacking, theft, condemnation, capture or seizure for more than 45 days; or |
||
(d) | arrest or detention for more than 45 days. |
(a) | in the case of an actual total loss, the date it happened or, if such date is not
known, the date on which the vessel was last reported; |
(b) | in the case of a constructive, compromised, agreed or arranged total loss, the
earliest of: |
(i) | the date notice of abandonment of the vessel is given to its
insurers; or |
(ii) | if the insurers do not admit such a claim, the date later determined
by a competent court of law to have been the date on which the total loss
happened; or |
(iii) | the date upon which a binding agreement as to such compromised or
arranged total loss has been entered into by the vessel’s insurers; |
(c) | in the case of a requisition for title, confiscation or compulsory acquisition,
the date it happened; and |
(d) | in the case of hijacking, theft, condemnation, capture, seizure, arrest or
detention, the date 45 days after the date upon which it happened. |
14
(a) | the date 180 days after its Total Loss Date; and |
||
(b) | the date upon which insurance proceeds or Requisition Compensation for such Total
Loss are paid by insurers or the relevant government entity. |
(a) | the proposed Transfer Date specified in the Transfer Certificate; and |
||
(b) | the date on which the Agent executes the Transfer Certificate. |
(a) | all moneys duly received by the Security Agent under or in respect of the Finance
Documents; |
(b) | any portion of the balance on any Account held by or charged to the Security
Agent at any time; |
(c) | the Security Interests, guarantees, security, powers and rights given to the
Security Agent under and pursuant to the Finance Documents including, without
limitation, the covenants given to the Security Agent in respect of all obligations of
any Obligor; |
(d) | all assets paid or transferred to or vested in the Security Agent or its agent or
received or recovered by the Security Agent or its agent in connection with any of the
Finance Documents whether from any Obligor or any other person; and |
(e) | all or any part of any rights, benefits, interests and other assets at any time
representing or deriving from any of the above, including all income and other sums at
any time received or receivable by the Security Agent or its agent in respect of the
same (or any part thereof). |
15
1.2 | Construction |
|
1.2.1 | Unless a contrary indication appears, any reference in any of the Finance Documents to: |
(a) | Sections, clauses and Schedules are to be construed as references to the
Sections and clauses of, and the Schedules to, the relevant Finance Document and
references to a Finance Document include its Schedules; |
(b) | a Finance Document or any other agreement or instrument is a reference to
that Finance Document or other agreement or instrument as it may from time to time be
amended, restated, novated or replaced, however fundamentally; |
||
(c) | words importing the plural shall include the singular and vice versa; |
||
(d) | a time of day are to Central European Time; |
(e) | any person includes its successors in title, permitted assignees or
transferees; |
(f) | the knowledge, awareness and/or beliefs (and similar expressions) of any
Obligor shall be construed so as to mean the knowledge, awareness and beliefs of the
director and officers of such Obligor, having made due and careful enquiry; |
||
(g) | agreed form means: |
(i) | where a Finance Document has already been executed by all of the
relevant parties, such Finance Document in its executed form; |
(ii) | prior to the execution of a Finance Document, the form of such
Finance Document separately agreed in writing between the Agent and the Borrower
as the form in which that Finance Document is to be executed or another form
approved at the request of the Borrower; |
(h) | approved by the Majority Lenders or approved by the Lenders means approved
in writing by the Agent acting on the instructions of the Majority Lenders or, as the
case may be, all of the Lenders (on such conditions as they may respectively impose)
and otherwise approved means approved in writing by the Agent (on such conditions as
the Agent may impose) and approval and approve shall be construed accordingly; |
16
(i) | assets includes present and future properties, revenues and rights of every
description; |
(j) | an authorisation means any authorisation, consent, concession, approval,
resolution, licence, exemption, filing, notarisation or registration; |
(k) | charter commitment means, in relation to a vessel, any charter or contract
for the use, employment or operation of that vessel or the carriage of people and/or
cargo or the provision of services by or from it and includes any agreement for
pooling or sharing income derived from any such charter or contract; |
||
(l) | control of an entity means: |
(i) | the power (whether by way of ownership of shares, proxy,
contract, agency or otherwise) to: |
(A) | cast, or control the casting of, more than 50% of the
maximum number of votes that might be cast at a general meeting of that
entity; or |
(B) | appoint or remove all, or the majority, of the
directors or other equivalent officers of that entity; or |
(C) | give directions with respect to the operating and
financial policies of that entity with which the directors or other
equivalent officers of that entity are obliged to comply; and/or |
(ii) | the holding beneficially of more than 50% of the issued share
capital of that entity (excluding any part of that issued share capital that
carries no right to participate beyond a specified amount in a distribution of
either profits or capital) (and, for this purpose, any Security Interest over
share capital shall be disregarded in determining the beneficial ownership of
such share capital), |
(m) | the term disposal or dispose means a sale, transfer or other disposal
(including by way of lease or loan but not including by way of loan of money) by a
person of all or part of its assets, whether by one transaction or a series of
transactions and whether at the same time or over a period of time, but not the
creation of a Security Interest; |
||
(n) | dollar/$ means the lawful currency of the United States of America; |
(o) | the equivalent of an amount specified in a particular currency (the
specified currency amount) shall be construed as a reference to the amount of the
other relevant currency which can be purchased with the specified currency amount in
the London foreign exchange market at or about 11 a.m. on the date the calculation
falls to be made for
spot delivery, as conclusively determined by the Agent (with the relevant exchange
rate of any such purchase being the Agent’s spot rate of exchange); |
17
(p) | a government entity means any government, state or agency of a state; |
(q) | a guarantee means any guarantee, letter of credit, bond, indemnity or
similar assurance against loss, or any obligation, direct or indirect, actual or
contingent, to purchase or assume any indebtedness of any person or to make an
investment in or loan to any person or to purchase assets of any person where, in
each case, such obligation is assumed in order to maintain or assist the ability of
such person to meet its indebtedness; |
(r) | indebtedness includes any obligation (whether incurred as principal or as
surety) for the payment or repayment of money, whether present or future, actual or
contingent; |
(s) | month means a period starting on one day in a calendar month and ending on
the numerically corresponding day in the next calendar month or the calendar month in
which it is to end, except that: |
(i) | if the numerically corresponding day is not a Business Day, that
period shall end on the next Business Day in that month (if there is one) or on
the immediately preceding Business Day (if there is not); and |
(ii) | if there is no numerically corresponding day in that month, that
period shall end on the last Business Day in that month, |
(t) | an obligation means any duty, obligation or liability of any kind; |
(u) | something being in the ordinary course of business of a person means
something that is in the ordinary course of that person’s current day-to-day
operational business (and not merely anything which that person is entitled to do
under its Constitutional Documents); |
(v) | pay, prepay or repay in clause 26 (Business restrictions) includes by way
of set-off, combination of accounts or otherwise; |
(w) | a person includes any individual, firm, company, corporation, government
entity or any association, trust, joint venture, consortium or partnership (whether
or not having separate legal personality); |
18
(x) | a regulation includes any regulation, rule, official directive, request or
guideline (whether or not having the force of law) of any governmental,
intergovernmental or supranational body, agency, department or regulatory,
self-regulatory or other authority or organisation and includes (without limitation)
any Basel 2 Regulation; |
(y) | right means any right, privilege, power or remedy, any proprietary interest
in any asset and any other interest or remedy of any kind, whether actual or
contingent, present or future, arising under contract or law, or in equity; |
(z) | trustee, fiduciary and fiduciary duty has in each case the meaning given to
such term under applicable law; |
(aa) | (i) the winding up, dissolution, or administration of person or (ii) a
receiver or administrative receiver or administrator in the context of insolvency
proceedings or security enforcement actions in respect of a person shall be construed
so as to include any equivalent or analogous proceedings or any equivalent and
analogous person or appointee (respectively) under the law of the jurisdiction in
which such person is established or incorporated or any jurisdiction in which such
person carries on business including (in respect of proceedings) the seeking or
occurrences of liquidation, winding-up, reorganisation, dissolution, administration,
arrangement, adjustment, protection or relief of debtors; |
(bb) | wholly-owned subsidiary has the meaning given to that term in section 1159
of the Companies Xxx 0000; and |
(cc) | a provision of law is a reference to that provision as amended or
re-enacted. |
1.2.2 | Where in this Agreement a provision includes a monetary reference level in one currency,
unless a contrary indication appears, such reference level is intended to apply equally to
its equivalent in other currencies as of the relevant time for the purposes of applying such
reference level to any other currencies. |
1.2.3 | Section, clause and Schedule headings are for ease of reference only. |
1.2.4 | Unless a contrary indication appears, a term used in any other Finance Document or in any
notice given under or in connection with any Finance Document has the same meaning in that
Finance Document or notice as in this Agreement. |
1.2.5 | A Default (other than an Event of Default) is continuing if it has not been remedied or
waived and an Event of Default is continuing if it has not been waived. |
19
1.2.6 | Unless a contrary indication appears, in the event of any inconsistency between the terms
of this Agreement and the terms of any other Finance Document when dealing with the same or
similar subject matter, the terms of this Agreement shall prevail. |
|
1.3 | Third party rights |
1.3.1 | Unless expressly provided to the contrary in a Finance Document for the benefit of a
Finance Party or another Indemnified Person, a person who is not a party to a Finance
Document has no right under the Contracts (Rights of Third Parties) Xxx 0000 (the Third
Parties Act) to enforce or to enjoy the benefit of any term of the relevant Finance Document. |
1.3.2 | Any Finance Document may be rescinded or varied by the parties to it without the consent
of any person who is not a party to it (unless otherwise provided by this Agreement). |
1.3.3 | An Indemnified Person who is not a party to a Finance Document may only enforce its rights
under that Finance Document through a Finance Party and if and to the extent and in such
manner as the Finance Party may determine. |
|
1.4 | Finance Documents |
|
Where any other Finance Document provides that this clause 1.4 shall apply to that Finance
Document, any other provision of this Agreement which, by its terms, purports to apply to all
or any of the Finance Documents and/or any Obligor shall apply to that Finance Document as if
set out in it but with all necessary changes. |
||
1.5 | Conflict of documents |
|
The terms of the Finance Documents (other than as relates to the creation and/or perfection
of security) are subject to the terms of this Agreement and, in the event of any conflict
between any provision of this Agreement and any provision of any Finance Document (other than
in relation to the creation and/or perfection of security) the provisions of this Agreement
shall prevail. |
20
2 | The Facility |
|
2.1 | The Facility |
|
Subject to the terms of this Agreement, the Lenders make available to the Borrower a term
loan facility in an aggregate amount equal to the Total Commitments. |
||
2.2 | Finance Parties’ rights and obligations |
|
2.2.1 | The obligations of each Finance Party under the Finance Documents are several. Failure by
a Finance Party to perform its obligations under the Finance Documents does not affect the
obligations of any other Party under the Finance Documents. No Finance Party is responsible
for the obligations of any other Finance Party under the Finance Documents. |
|
2.2.2 | The rights of each Finance Party under or in connection with the Finance Documents are
separate and independent rights and any debt arising under the Finance Documents to a Finance
Party from an Obligor shall be a separate and independent debt. |
|
2.2.3 | A Finance Party may, except as otherwise stated in the Finance Documents (including
clauses 30.24 (All enforcement action through the Security Agent)) and 31.2 (Finance Parties
acting together), separately enforce its rights under the Finance Documents. |
|
3 | Purpose |
|
3.1 | Purpose |
|
The Borrower shall apply all amounts borrowed under the Facility in accordance with this
clause 3. |
||
3.2 | Completion of delivery |
|
The Commitments shall initially be made solely for the purpose of assisting the Borrower in
paying part of the final delivery instalment to the Builder or the Builder’s order under the
Building Contract upon delivery of the Ship. |
||
3.3 | Monitoring |
|
No Finance Party is bound to monitor or verify the application of any amount borrowed
pursuant to this Agreement. |
21
4 | Conditions of Utilisation |
|
4.1 | Initial conditions precedent |
|
The Borrower may not deliver a Utilisation Request unless the Agent, or its duly authorised
representative, has received all of the documents and other evidence listed in Part 1 of
Schedule 3 (Conditions precedent to Utilisation) in form and substance satisfactory to the
Agent. |
||
4.2 | Conditions precedent on Delivery |
|
The Total Commitments shall only become available for borrowing under this Agreement if the
Agent, or its duly authorised representative, has received all of the documents and evidence
listed in Part 2 of Schedule 3 (Conditions precedent on Delivery) in form and substance
satisfactory to the Agent. |
||
4.3 | Notice to Lenders |
|
The Agent shall notify the Borrower and the Lenders promptly upon receiving and being
satisfied with all of the documents and evidence delivered to it under this clause 4. |
||
4.4 | Further conditions precedent |
|
The Lenders will only be obliged to comply with clause 5.4 (Lenders’ participation) if on the
date of the Utilisation Request and on the proposed Utilisation Date: |
(a) | no Default is continuing or would result from the proposed Utilisation; and |
||
(b) | all of the representations set out in clause 18 (Representations) are true. |
4.5 | Waiver of conditions precedent |
|
The conditions in this clause 4 are inserted solely for the benefit of the Finance Parties
and may be waived on their behalf in whole or in part and with or without conditions by the
Agent acting on the instructions of the Majority Lenders. |
22
5 | Utilisation |
|
5.1 | Delivery of a Utilisation Request |
|
The Borrower may utilise the Facility by delivery to the Agent of a duly completed
Utilisation Request not later than 11:00 a.m. five Business Days before the proposed
Utilisation Date. |
||
5.2 | Completion of a Utilisation Request |
|
5.2.1 | A Utilisation Request is irrevocable and will not be regarded as having been duly
completed unless: |
(a) | the proposed Utilisation Date is a Business Day falling on or before the
Last Availability Date; |
(b) | the currency and amount of the Utilisation comply with clause 5.3 (Currency
and amount); |
||
(c) | the proposed Interest Period complies with clause 9 (Interest Periods); and |
(d) | it identifies the purpose for the Utilisation and that purpose complies
with clause 3 (Purpose). |
5.3 | Currency and amount |
5.4 | Lenders’ participation |
5.4.1 | If the conditions set out in this Agreement have been met, each Lender shall make its
participation in the Loan available by the Utilisation Date through its Facility Office. |
5.4.2 | The amount of each Lender’s participation in the Loan will be equal to the proportion
borne by its Commitment to the Total Commitments immediately prior to making the Loan. |
5.4.3 | The Agent shall promptly notify each Lender of the amount of the Loan and the amount of
its participation in the Loan, in each case by 11:00 a.m. four Business Days before the
proposed Utilisation Date. |
5.4.4 | The Agent shall pay all amounts received by it in respect of the Loan (and its own
participation in it, if any) to the Borrower or for its account in accordance with the
instructions contained in the Utilisation Request. |
23
6 | Repayment |
6.1 | Repayment |
|
On the Repayment Date (without prejudice to any other provision of this Agreement), the Loan
shall be repaid in full, together with a premium of 3% of the Loan then outstanding. |
7 | Illegality, prepayment and cancellation |
7.1 | Illegality |
(a) | that Lender shall promptly notify the Agent upon becoming aware of that
event; |
(b) | upon the Agent notifying the Borrower, the Commitment of that Lender will
be immediately cancelled; and |
(c) | the Borrower shall repay that Lender’s participation in the Loan on the
last day of the Interest Period occurring after the Agent has notified the Borrower
or, if earlier, the date specified by the Lender in the notice delivered to the Agent
(being no earlier than the last day of any applicable grace period permitted by law). |
7.2 | Change of control |
|
7.2.1 | The Borrower shall promptly notify the Agent upon any Obligor becoming aware of a Change
of Control. |
7.2.2 | If a Change of Control occurs, the Agent may, and shall if so directed by the Majority
Lenders, by notice to the Borrower, cancel the Total Commitments with effect from a date
specified in that notice which is at least 30 days after the giving of the notice and declare
that all or part of the Loan be payable on demand after such date, on which date it shall
become payable on demand by the Agent on the instructions of the Majority Lenders. |
7.3 | Voluntary prepayment |
24
7.4 | Voluntary prepayment fee |
|
In the event a voluntary prepayment is made pursuant to clause 7.3 (Voluntary prepayment),
the Borrower shall pay to the Agent (for distribution to the Lenders) a fee calculated in the
following manner: |
||
7.4.1 | in the case of a voluntary prepayment made before the date falling 18 months after the
Utilisation Date, in an amount determined by the Lenders to be the present value of all
future interest payments in respect of the amount prepaid pursuant to clause 7.3 (Voluntary
prepayment) from the date of prepayment until the Repayment Date using a discount rate of the
rate applicable to US treasury bonds as at the date of the notice of prepayment under clause
7.3 (Voluntary prepayment) for a period maturing on or about the Repayment Date, such fee to
be advised by the Lenders to the Agent not later than five Business Days prior to the
proposed date of prepayment and the Agent shall promptly notify the Borrower of such fee; |
7.4.2 | in the case of a voluntary prepayment made on or after the date falling 18 months after
the Utilisation Date but before the date falling 24 months after the Utilisation Date at 2%
of the amount prepaid pursuant to clause 7.3 (Voluntary prepayment) together with accrued
interest; and |
7.4.3 | in the case of a voluntary prepayment made on or after the date falling 24 months after
the Utilisation Date but before the Repayment Date at 3% of the amount prepaid pursuant to
clause 7.3 (Voluntary prepayment) together with accrued interest. |
7.5 | Right of replacement or cancellation and prepayment in relation to a single Lender |
|
7.5.1 | If: |
(a) | any sum payable to any Lender by an Obligor is required to be increased
under clause 12.2 (Tax gross-up); or |
(b) | any Lender claims indemnification from the Borrower under clause 12.3 (Tax
indemnity) or clause 13.1 (Increased costs), |
the Borrower may, whilst the circumstance giving rise to the requirement for that increase or
indemnification continues, give the Agent notice of cancellation of the Commitment of that
Lender and its intention to procure the repayment of that Lender’s participation in the Loan
or give the Agent notice of its intention to replace that Lender in accordance with clause
7.5.4.
|
||
7.5.2 | On receipt of a notice referred to in clause 7.5.1 above, the Commitment of that Lender
shall immediately be reduced to zero. |
25
7.5.3 | On the last day of each Interest Period which ends after the Borrower has given notice
under clause 7.5.1 above (or, if earlier, the date specified by the Borrower in that notice),
the Borrower shall repay that Lender’s participation in the Loan. |
7.5.4 | The Borrower may, in the circumstances set out in clause 7.5.1, on 30 Business Days’ prior
notice to the Agent and that Lender, replace that Lender by requiring that Lender to transfer
(and, to the extent permitted by law, that Lender shall transfer) pursuant to clause 28
(Changes to the Lenders) all (and not part only) of its rights and obligations under this
Agreement to a Lender or other bank, financial institution, trust, fund or other entity
selected by the Borrower which confirms its willingness to assume and does assume all the
obligations of the transferring Lender in accordance with clause 28 (Changes to the Lenders)
for a purchase price in cash or other cash payment payable at the time of the transfer equal
to the aggregate of: |
(a) | the outstanding principal amount of such Lender’s participation in the
Loan; |
||
(b) | all accrued interest owing to such Lender; |
(c) | the Break Costs which would have been payable to such Lender pursuant to
clause 10.1 (Break Costs) had the Borrower prepaid in full that Lender’s
participation in the Loan on the date of the transfer; and |
(d) | all other amounts payable to that Lender under the Finance Documents on the
date of the transfer. |
7.5.5 | The replacement of a Lender pursuant to clause 7.5.4 shall be subject to the following
conditions: |
(a) | the Borrower shall have no right to replace the Agent; |
||
(b) | neither the Agent nor any Lender shall have any obligation to find a
replacement Lender; and |
||
(c) | in no event shall the Lender replaced under clause 7.5.4 be required to pay
or surrender any of the fees received by such Lender pursuant to the Finance
Documents. |
7.6 | Total Loss |
(a) | the Total Commitments will be reduced to zero; and |
||
(b) | the Borrower shall prepay the Loan. |
26
7.7 | Mandatory cancellation |
(a) | the Building Contract is for any reason and by any method cancelled,
terminated or rescinded; or |
(b) | a competent court or arbitration panel decides that the Building Contract
has been validly cancelled, terminated or rescinded; or |
(c) | the Borrower disposes of its rights under the Building Contract (whether
this be by way of assignment, novation or otherwise) or the Borrower wrongfully
cancels, terminates or rescinds the Building Contract, |
then the Agent may, and shall if so directed by the Majority Lenders, by notice to the
Borrower with effect from the date ten Business Days after the giving of such notice (or such
later date as may be approved in advance by the Majority Lenders) cancel the Total
Commitments and the Total Commitments shall then be reduced to zero.
|
||
7.8 | Beta Ship |
|
If the Beta Ship becomes a Total Loss (as defined in the Beta Facility Agreement), the
Borrower or the Parent shall procure that on the Total Loss Repayment Date (as defined in the
Beta Facility Agreement) the net total loss proceeds remaining following the prepayment in
full of the sums owing under the Beta Facility Agreement are applied (and the payment of any
reasonable expenses as may be approved) in part prepayment of the Loan. |
||
7.9 | Automatic cancellation |
|
Any part of the Total Commitments which has not become available by the Last Availability
Date shall be automatically cancelled at close of business in London on the Last Availability
Date. |
||
7.10 | Restrictions |
|
7.10.1 | Any notice of cancellation or prepayment given by any Party under this clause 7 shall be
irrevocable and, unless a contrary indication appears in this Agreement, shall specify the
date or dates upon which the relevant cancellation or prepayment is to be made and the amount
of that cancellation or prepayment. |
7.10.2 | Any prepayment under this Agreement shall be made together with accrued interest on the
amount prepaid and, subject to any Break Costs, without premium or penalty save for payment
of the fee under clause 7.4 (Voluntary prepayment fee). |
7.10.3 | The Borrower may not reborrow any part of the Facility which is prepaid. |
27
7.10.4 | The Borrower shall not repay or prepay all or any part of the Loan or cancel all or any
part of the Commitments except at the times and in the manner expressly provided for in this
Agreement. |
7.10.5 | No amount of the Total Commitments cancelled under this Agreement may be subsequently
reinstated. |
7.10.6 | If the Agent receives a notice under this clause 7 it shall promptly forward a copy of that
notice to either the Borrower or the affected Lender, as appropriate. |
7.10.7 | If the Total Commitments are partially reduced under this Agreement (other than under
clause 7.1 (Illegality) and clause 7.5 (Right of cancellation and prepayment in relation to a
single Lender)), the Commitments of the Lenders shall be reduced rateably. |
28
8 | Interest |
|
8.1 | Rate of interest |
|
The rate of interest on the Loan is fixed at 9% per annum. |
||
8.2 | Payment of interest |
|
The Borrower shall pay accrued interest on the Loan on the last day of each Interest Period. |
||
8.3 | Default interest |
|
8.3.1 | If an Obligor fails to pay any amount payable by it under a Finance Document on its due
date, interest shall accrue on the overdue amount from the due date up to the date of actual
payment (both before and after judgment) at a rate which, subject to clause 8.3.2 below, is
2.5% higher than the rate which would have been payable if the overdue amount had, during the
period of non-payment, constituted the Loan for successive Interest Periods, each of a
duration selected by the Agent (acting reasonably). Any interest accruing in accordance with
this clause 8.3 shall be immediately payable by the Obligor on demand by the Agent. |
|
8.3.2 | If any overdue amount consists of all or part of the Loan which became due on a day which
was not the last day of an Interest Period relating to the Loan or the relevant part of it: |
(a) | the first Interest Period for that overdue amount shall have a duration
equal to the unexpired portion of the current Interest Period relating to the Loan;
and |
(b) | the rate of interest applying to the overdue amount during that first
Interest Period shall be 2.5% higher than the rate which would have applied if the
overdue amount had not become due. |
8.3.3 | Default interest (if unpaid) arising on an overdue amount will be compounded with the
overdue amount at the end of each Interest Period applicable to that overdue amount but will
remain immediately due and payable. |
9 | Interest Periods |
|
9.1 | Interest Periods |
|
9.1.1 | Each Interest Period for the Loan shall be for a period running to either 31 January, 30
April, 31 July or 31 October (as the case may be) in any given year. |
9.1.2 | No Interest Period shall extend beyond the Repayment Date. |
29
9.1.3 | The first Interest Period for the Loan shall start on the Utilisation Date and shall
expire at the end of the relevant Interest Period determined pursuant to clause 9.1.1 and
each subsequent Interest Period for the Loan shall start on the last day of its preceding
Interest Period. |
|
9.2 | Non-Business Days |
|
If an Interest Period would otherwise end on a day which is not a Business Day, that Interest
Period will instead end on the next Business Day in that calendar month (if there is one) or
the preceding Business Day (if there is not). |
||
10 | Break Costs |
|
10.1 | Break Costs |
|
10.1.1 | The Borrower shall, within three Business Days of demand by a Finance Party, pay to that
Finance Party its Break Costs attributable to all or any part of the Loan or Unpaid Sum being
paid by the Borrower on a day other than the last day of an Interest Period for the Loan or
Unpaid Sum or relevant part of it. |
10.1.2 | Each Lender shall, as soon as reasonably practicable after a demand by the Agent, provide a
certificate confirming the amount of its Break Costs for any Interest Period in which they
accrue. Such certificate shall (subject to the proviso hereto) include a breakdown of such
Break Costs, provided that the lenders shall not be required to disclose any confidential
and/or price-sensitive information in any such certificate, and shall be sent to the Borrower
together with the demand for payment. |
|
11 | Fees |
|
11.1 | Arrangement fee |
|
The Borrower shall pay to the Arranger an arrangement fee in the amount and at the times
agreed in a Fee Letter. |
||
11.2 | Agency fee |
|
The Borrower shall pay to the Agent (for its own account) an agency fee in the amount and at
the times agreed in a Fee Letter. |
||
The Borrower shall pay to the Security Agent (from its own account) a security agency fee in
the amount and at the times agreed in a Fee Letter. |
30
12 | Tax gross-up and indemnities |
|
12.1 | Definitions |
|
12.1.1 | In this Agreement: |
|
Protected Party means a Finance Party or, in relation to clause 14.4 (Indemnity concerning
security) and clause 14.7 (Interest) insofar as it relates to interest on any amount demanded
by that Indemnified Person under clause 14.4 (Indemnity concerning security), any Indemnified
Person, which is or will be subject to any liability, or required to make any payment, for or
on account of Tax in relation to a sum received or receivable (or any sum deemed for the
purposes of Tax to be received or receivable) under a Finance Document. |
||
Tax Credit means a credit against Tax or any relief or remission for Tax (or its repayment). |
||
Tax Deduction means a deduction or withholding for or on account of Tax from a payment under
a Finance Document. |
||
Tax Payment means either the increase in a payment made by an Obligor to a Finance Party
under clause 12.2 (Tax gross-up) or a payment under clause 12.3 (Tax indemnity). |
||
12.1.2 | Unless a contrary indication appears, in this clause 12 a reference to determines or
determined means a determination made in the absolute discretion of the person making the
determination. |
|
12.2 | Tax gross-up |
|
12.2.1 | Each Obligor shall make all payments to be made by it under any Finance Document without
any Tax Deduction, unless a Tax Deduction is required by law. |
12.2.2 | The Borrower shall, promptly upon becoming aware that an Obligor must make a Tax Deduction
(or that there is any change in the rate or the basis of a Tax Deduction), notify the Agent
accordingly. Similarly, a Lender shall notify the Agent on becoming so aware in respect of a
payment payable to that Lender. If the Agent receives such notification from a Lender it
shall notify the Borrower and that Obligor. |
12.2.3 | If a Tax Deduction is required by law to be made by an Obligor, the amount of the payment
due from that Obligor under the relevant Finance Document shall be increased to an amount
which (after making any Tax Deduction) leaves an amount equal to the payment which would have
been due if no Tax Deduction had been required. |
31
12.2.4 | If an Obligor is required to make a Tax Deduction, that Obligor shall make that Tax
Deduction and any payment required in connection with that Tax Deduction within the time
allowed and in the minimum amount required by law. |
12.2.5 | Within 30 days of making either a Tax Deduction or any payment required in connection with
that Tax Deduction, the Obligor making that Tax Deduction shall deliver to the Agent for the
Finance Party entitled to the payment evidence reasonably satisfactory to that Finance Party
that the Tax Deduction has been made or (as applicable) any appropriate payment paid to the
relevant taxing authority. |
|
12.3 | Tax credit |
12.3.1 | Where any payment has been made subject to a Tax Deduction, a Finance Party agrees to use
its commercially reasonable endeavours to complete any procedural formalities necessary for
the relevant Finance Party to obtain any Tax Credit available as a result of the payment
being made subject to a Tax Deduction. |
12.3.2 | If the Borrower makes a Tax Payment and the relevant Finance Party in its absolute
discretion determines that: |
(a) | a Tax Credit is attributable either to an increased payment of which that
Tax Payment forms part, or to that Tax Payment; and |
||
(b) | it has used and retained that Tax Credit, |
the Finance Party must pay an amount to the Borrower which that Finance Party determines will
leave it (after that payment) in the same after-Tax position as it would have been if the Tax
Payment had not been required to be made by the Borrower.
|
||
12.4 | Tax indemnity |
|
12.4.1 | The Borrower shall (within three Business Days of demand by the Agent) pay to a Protected
Party an amount equal to the loss, liability or cost which that Protected Party determines
will be or has been (directly or indirectly) suffered for or on account of Tax by that
Protected Party in respect of a Finance Document. |
|
12.4.2 | Clause 12.4.1 above shall not apply: |
(a) | with respect to any Tax assessed on a Finance Party: |
(i) | under the law of the jurisdiction in which that Finance Party is
incorporated or, if different, the jurisdiction (or jurisdictions) in which that
Finance Party is treated as resident for tax purposes; or |
32
(ii) | under the law of the jurisdiction in which that Finance Party’s
Facility Office is located in respect of amounts received or receivable in that
jurisdiction, |
(b) | to the extent a loss, liability or cost is compensated for by an increased
payment under clause 12.2 (Tax gross-up). |
12.4.3 | A Protected Party making, or intending to make a claim under clause 12.4.1 above shall
promptly notify the Agent of the event which will give, or has given, rise to the claim,
following which the Agent shall notify the Borrower. |
12.4.4 | A Protected Party shall, on receiving a payment from an Obligor under this clause 12.3,
notify the Agent. |
|
12.5 | Indemnities on after Tax basis |
12.5.1 | If and to the extent that any sum payable to any Protected Party by the Borrower under any
Finance Document by way of indemnity or reimbursement proves to be insufficient, by reason of
any Tax suffered thereon, for that Protected Party to discharge the corresponding liability
to a third party, or to reimburse that Protected Party for the cost incurred by it in
discharging the corresponding liability to a third party, the Borrower shall pay that
Protected Party such additional sum as (after taking into account any Tax suffered by that
Protected Party on such additional sum) shall be required to make up the relevant deficit. |
12.5.2 | If and to the extent that any sum (the Indemnity Sum) constituting (directly or indirectly)
an indemnity to any Protected Party but paid by the Borrower to any person other than that
Protected Party, shall be treated as taxable in the hands of the Protected Party, the
Borrower shall pay to that Protected Party such sum (the Compensating Sum) as (after taking
into account any Tax suffered by that Protected Party on the compensating sum) shall
reimburse that Protected Party for any Tax suffered by it in respect of the indemnity sum. |
12.5.3 | For the purposes of this clause 12.5 a sum shall be deemed to be taxable in the hands of a
Protected Party if it falls to be taken into account in computing the profits or gains of
that Protected Party for the purposes of Tax and, if so, that Protected Party shall be deemed
to have suffered Tax on the relevant sum at the rate of Tax applicable to that Protected
Party’s profits or gains for the period in which the payment of the relevant sum falls to be
taken into account for the purposes of such Tax. |
33
12.6 | Stamp taxes |
|
The Borrower shall pay and, within three Business Days of demand, indemnify each Finance
Party against any cost, loss or liability that Finance Party incurs in relation to all stamp
duty, registration and other similar Taxes payable in respect of any Finance Document. |
||
12.7 | Value added tax |
|
12.7.1 | All amounts set out, or expressed in a Finance Document to be payable by any party to a
Finance Party which (in whole or in part) constitute the consideration for a supply or
supplies for VAT purposes shall be deemed to be exclusive of any VAT which is chargeable on
such supply or supplies, and accordingly, subject to clause 12.7.3 below, if VAT is or
becomes chargeable on any supply made by any Finance Party to any party under a Finance
Document, that party shall pay to the Finance Party (in addition to and at the same time as
paying any other consideration for such supply) an amount equal to the amount of such VAT
(and such Finance Party shall promptly provide an appropriate VAT invoice to such party). |
|
12.7.2 | If VAT is or becomes chargeable on any supply made by any Finance Party (the Supplier) to
any other Finance Party (the Recipient) under a Finance Document, and any party to a Finance
Document other than the Recipient (the Subject Party) is required by the terms of any Finance
Document to pay an amount equal to the consideration for such supply to the Supplier (rather
than being required to reimburse the Recipient in respect of that consideration), the Subject
Party shall also pay to the Supplier (in addition to and at the same time as paying such
amount) an amount equal to the amount of such VAT. The Recipient will promptly pay to the
Subject Party an amount equal to any credit or repayment obtained by the Recipient from the
relevant tax authority which the Recipient reasonably determines is in respect of such VAT. |
|
12.7.3 | Where a Finance Document requires any party to it to reimburse or indemnify a Finance Party
for any cost or expense, that party shall reimburse or indemnify (as the case may be) such
Finance Party for the full amount of such cost or expense, including such part thereof as
represents VAT save to the extent that such Finance Party reasonably determines that it is
entitled to credit or repayment of in respect of such VAT from the relevant tax authority. |
|
12.7.4 | Any reference in this clause 12.7 to any Party shall, at any time when such Party is
treated as a member of a group for VAT purposes, include (where appropriate and unless the
context otherwise requires) a reference to the representative member of such group at such
time (the term “representative member” to have the same meaning as in the Value Added Tax Act
1994). |
34
13 | Increased Costs |
|
13.1 | Increased Costs |
|
13.1.1 | Subject to clause 13.3 (Exceptions), the Borrower shall, within three Business Days of a
demand by the Agent, pay for the account of a Finance Party the amount of any Increased Costs
incurred by that Finance Party or any of its Affiliates as a result of (a) the introduction
of or any change in (or in the interpretation, administration or application of) any law or
regulation or (b) compliance with any law or regulation in either case made after the date of
this Agreement. |
|
13.1.2 | In this Agreement Increased Costs means: |
(a) | a reduction in the rate of return from the Facility or on a Finance Party’s
(or its Affiliate’s) overall capital; |
||
(b) | an additional or increased cost; or |
||
(c) | a reduction of any amount due and payable under any Finance Document, |
which is incurred or suffered by a Finance Party or any of its Affiliates to the extent that
it is attributable to that Finance Party having entered into its Commitment or funding or
performing its obligations under any Finance Document.
|
||
13.2 | Increased Cost claims |
|
13.2.1 | A Finance Party intending to make a claim pursuant to clause 13.1 (Increased costs) shall
notify the Agent of the event giving rise to the claim, following which the Agent shall
promptly notify the Borrower. |
13.2.2 | Each Finance Party shall, as soon as practicable after a demand by the Agent, provide a
certificate confirming the amount of its Increased Costs. Such certificate shall include a
breakdown of such Increased Costs, provided that the Finance Parties shall not be required to
disclose any confidential or price-sensitive information in any such certificate, and shall
be sent to the Borrower together with the demand for payment |
|
13.3 | Exceptions |
13.3.1 | Clause 13.1 (Increased Costs) does not apply to the extent any Increased Cost is: |
(a) | attributable to a Tax Deduction required by law to be made by an Obligor; |
35
(b) | compensated for by clause 12.3 (Tax indemnity) (or would have been
compensated for under clause 12.3 (Tax indemnity) but was not so compensated solely
because any of the exclusions in clause 12.4.2 (Tax indemnity) applied); or |
(c) | attributable to the wilful breach by the relevant Finance Party or its
Affiliates of any law or regulation. |
13.3.2 | In this clause 13.3, a reference to a Tax Deduction has the same meaning given to the term
in clause 12.1 (Definitions). |
14 | Other indemnities |
|
14.1 | Currency indemnity |
|
14.1.1 | If any sum due from an Obligor under the Finance Documents (a Sum), or any order, judgment
or award given or made in relation to a Sum, has to be converted from the currency (the First
Currency) in which that Sum is payable into another currency (the Second Currency) for the
purpose of: |
(a) | making or filing a claim or proof against that Obligor; and/or |
||
(b) | obtaining or enforcing an order, judgment or award in relation to any
litigation or arbitration proceedings, |
that Obligor shall, as an independent obligation, within three Business Days of demand by a
Finance Party, indemnify each Finance Party to whom that Sum is due against any Losses
arising out of or as a result of the conversion including any discrepancy between (i) the
rate of exchange used to convert that Sum from the First Currency into the Second Currency
and (ii) the rate or rates of exchange available to that person at the time of its receipt of
that Sum.
|
||
14.1.2 | Each Obligor waives any right it may have in any jurisdiction to pay any amount under the
Finance Documents in a currency or currency unit other than that in which it is expressed to
be payable. |
|
14.2 | Other indemnities |
|
The Borrower shall (or shall procure that another Obligor will), within three Business Days
of demand by a Finance Party, indemnify each Finance Party against any and all Losses
incurred by that Finance Party as a result of: |
(a) | the occurrence of any Event of Default; |
36
(b) | a failure by an Obligor to pay any amount due under a Finance Document on
its due date, including without limitation, any and all Losses arising as a result of
clause 32 (Sharing among the Finance Parties); |
(c) | funding, or making arrangements to fund, its participation in the Loan
requested by the Borrower in a Utilisation Request but not made by reason of the
operation of any one or more of the provisions of this Agreement (other than by
reason of default or negligence by that Finance Party alone); or |
(d) | the Loan (or part of the Loan) not being prepaid in accordance with a
notice of prepayment given by the Borrower. |
14.3 | Indemnity to the Agent and the Security Agent |
(a) | investigating any event which it reasonably believes is a Default; |
(b) | acting or relying on any notice, request or instruction which it reasonably
believes to be genuine, correct and appropriately authorised; or |
(c) | any action taken by the Agent or the Security Agent or any of their
representatives, agents or contractors in connection with any powers conferred by any
Security Document to remedy any breach of any Obligor’s obligations under the Finance
Documents. |
14.4 | Indemnity concerning security |
|
14.4.1 | The Borrower shall (or shall procure that another Obligor will) promptly indemnify each
Indemnified Person against any and all Losses incurred by it in connection with: |
(a) | the taking, holding, protection or enforcement of the Security Documents; |
(b) | the exercise or purported exercise of any of the rights, powers,
discretions and remedies vested in the Security Agent and each Receiver by the
Finance Documents or by law unless and to the extent that it was caused by its gross
negligence or wilful misconduct; |
(c) | any claim (whether relating to the environment or otherwise) made or
asserted against the Indemnified Person which would not have arisen but for the
execution or enforcement of one or more Finance Documents (unless and to the extent
it is caused by the gross negligence or wilful misconduct of that Indemnified
Person); or |
||
(d) | any breach by any Obligor of the Finance Documents. |
37
14.4.2 | The Security Agent may, in priority to any payment to the other Finance Parties, indemnify
itself out of the Trust Property in respect of, and pay and retain, all sums necessary to
give effect to the indemnity in this clause 14.4 and shall have a lien on the Security
Documents and the proceeds of the enforcement of those Security Documents for all monies
payable to it. |
|
14.5 | Continuation of indemnities |
|
The indemnities by the Borrower in favour of the Indemnified Persons contained in this
Agreement shall continue in full force and effect notwithstanding any breach by any Finance
Party or the Borrower of the terms of this Agreement, the repayment or prepayment of the
Loan, the cancellation of the Total Commitments or the repudiation by the Agent or the
Borrower of this Agreement. |
||
14.6 | Third Parties Act |
|
Each Indemnified Person may rely on the terms of clause 14.4 (Indemnity concerning security)
and clauses 12 (Tax gross-up and indemnities) and 14.7 (Interest) insofar as it relates to
interest on any amount demanded by that Indemnified Person under clause 14.4 (Indemnity
concerning security), subject to clause 1.3 (Third party rights) and the provisions of the
Third Parties Act. |
||
14.7 | Interest |
|
Moneys becoming due by the Borrower to any Indemnified Person under the indemnities contained
in this clause 14 or elsewhere in this Agreement shall be paid on demand made by such
Indemnified Person and shall be paid together with interest on the sum demanded from the date
of demand therefor to the date of reimbursement by the Borrower to such Indemnified Person
(both before and after judgment) at the rate referred to in clause 8.3 (Default interest). |
||
14.8 | Exclusion of liability |
|
No Indemnified Person will be in any way liable or responsible to any Obligor (whether as
mortgagee in possession or otherwise) who is a Party or is a party to a Finance Document to
which this clause applies for any loss or liability arising from any act, default, omission
or misconduct of that Indemnified Person, except to the extent caused by its own gross
negligence or wilful misconduct. Any Indemnified Person may rely on this clause 14.8 subject
to clause 1.3 (Third party rights) and the provisions of the Third Parties Act. |
38
15 | Mitigation by the Lenders |
|
15.1 | Mitigation |
|
15.1.1 | Each Finance Party shall, in consultation with the Borrower, take all reasonable steps to
mitigate any circumstances which arise and which would result in any amount becoming payable
under or pursuant to, or cancelled pursuant to, any of clause 7.1 (Illegality), clause 12
(Tax gross-up and indemnities) or clause 13 (Increased costs) including (but not limited to)
transferring its rights and obligations under the Finance Documents to another Affiliate or
Facility Office. |
|
15.1.2 | Clause 15.1.1 does not in any way limit the obligations of any Obligor under the Finance
Documents. |
|
15.2 | Limitation of liability |
|
15.2.1 | The Borrower shall indemnify each Finance Party for all costs and expenses incurred by that
Finance Party as a result of steps taken by it under clause 15.1 (Mitigation). |
|
15.2.2 | A Finance Party is not obliged to take any steps under clause 15.1 (Mitigation) if, in the
opinion of that Finance Party (acting reasonably), to do so might be prejudicial to it. |
|
16 | Costs and expenses |
|
16.1 | Transaction expenses |
|
The Borrower shall promptly within five Business Days of demand pay to the Agent and/or each
other Finance Party, the amount of all costs and expenses (including fees, costs and expenses
of legal advisers and insurance and other consultants and advisers) reasonably incurred by
any of them (and by any Receiver) in connection with the negotiation, preparation, printing,
execution, syndication, registration and perfection and any release, discharge or
reassignment of: |
(a) | this Agreement and any other documents referred to in this Agreement and
the Security Documents; |
(b) | any other Finance Documents executed or proposed to be executed after the
date of this Agreement; or |
(c) | any Security Interest expressed or intended to be granted by a Finance
Document. |
39
16.2 | Amendment costs |
|
If an Obligor requests an amendment, waiver or consent, the Borrower shall, within five
Business Days of demand by the Agent, reimburse the Agent for the amount of all costs and
expenses (including fees, costs and expenses of legal advisers and insurance and other
consultants and advisers) reasonably incurred by the Agent and the Security Agent (and by any
Receiver) in responding to, evaluating, negotiating or complying with that request or
requirement. |
||
16.3 | Enforcement, preservation and other costs |
|
The Borrower shall on demand by a Finance Party, pay to each Finance Party the amount of all
costs and expenses (including fees, costs and expenses of legal advisers and insurance and
other consultants, brokers, surveyors and advisers) incurred by that Finance Party in
connection with: |
(a) | the enforcement of, or the preservation of any rights under, any Finance
Document and any proceedings initiated by or against any Indemnified Person and as a
consequence of holding the Charged Property or enforcing those rights; or |
(b) | any inspection carried out under clause 22.8 (Inspection and notice of
drydockings) or any survey carried out under clause 22.16 (Survey report). |
40
17 | Guarantee and indemnity |
17.1 | Guarantee and indemnity |
|
The Parent irrevocably and unconditionally: |
(a) | guarantees to the Security Agent (as trustee for the Finance Parties) and
the other Finance Parties punctual performance by each other Obligor of all such
Obligor’s obligations under the Finance Documents; |
(b) | undertakes with the Security Agent (as trustee for the Finance Parties) and
the other Finance Parties that whenever another Obligor does not pay any amount when
due under or in connection with any Finance Document, it shall immediately on demand
pay that amount as if it was the principal obligor; and |
(c) | agrees with the Agent (as trustee for the Finance Parties) and the other
Finance Parties that if any obligation guaranteed by it is or becomes unenforceable,
invalid or illegal, it will, as an independent and primary obligation indemnify that
Finance Party immediately on demand against any cost, loss or liability it incurs as
a result of the Borrower not paying any amount which would, but for such
unenforceability, invalidity or illegality, have been payable by the Borrower under
any Finance Document on the date when it would have been due. The amount payable by
the Parent under this indemnity will not exceed the amount it would have had to pay
under this clause 17.1 if the amount claimed had been recoverable on the basis of a
guarantee. |
17.2 | Continuing guarantee |
|
This guarantee is a continuing guarantee and will extend to the ultimate balance of sums
payable by any Obligor under the Finance Documents, regardless of any intermediate payment or
discharge in whole or in part. |
17.3 | Reinstatement |
|
If any discharge, release or arrangement (whether in respect of the obligations of an Obligor
or any security for those obligations or otherwise) is made by a Finance Party in whole or in
part on the basis of any payment, security or other disposition which is avoided or must be
restored in insolvency, liquidation, administration or otherwise, without limitation, then
the liability of the Parent under this clause 17 will continue or be reinstated as if the
discharge, release or arrangement had not occurred. |
41
17.4 | Waiver of defences |
|
The obligations of the Parent under this clause 17 will not be affected by an act, omission,
matter or thing (whether or not known to it or any Finance Party) which, but for this clause,
would reduce, release or prejudice any of its obligations under this clause 17 including
(without limitation): |
(a) | any time, waiver or consent granted to, or composition with, any Obligor or
other person; |
(b) | the release of any other Obligor or any other person under the terms of any
composition or arrangement with any creditor of any other Obligor; |
(c) | the taking, variation, compromise, exchange, renewal or release of, or
refusal or neglect to perfect, take up or enforce, any rights against, or security
over assets of, any Obligor or other person or any non-presentation or non-observance
of any formality or other requirement in respect of any instrument or any failure to
realise the full value of any security; |
(d) | any incapacity or lack of power, authority or legal personality of or
dissolution or change in the members or status of an Obligor or any other person; |
(e) | any amendment, novation, supplement, extension, restatement (however
fundamental and whether or not more onerous) or replacement of any Finance Document
or any other document or security; |
(f) | any unenforceability, illegality or invalidity of any obligation of any
person under any Finance Document or any other document or security; or |
||
(g) | any insolvency or similar proceedings. |
17.5 | Immediate recourse |
|
The Parent waives any right it may have of first requiring any Finance Party (or any trustee
or agent on its behalf) to proceed against or enforce any other rights or security or claim
payment from any person before claiming from the Parent under this clause 17. This waiver
applies irrespective of any law or any provision of a Finance Document to the contrary. |
17.6 | Appropriations |
|
Until all amounts which may be or become payable by the Obligors under or in connection with
the Finance Documents have been irrevocably paid in full, each Finance Party (or any trustee
or agent on its behalf) may: |
(a) | refrain from applying or enforcing any other moneys, security or rights
held or received by that Finance Party (or any trustee or agent on its behalf) in
respect of those amounts, or apply and enforce the same in such manner and order as
it sees fit (whether against those amounts or otherwise) and the Parent shall not be
entitled to the benefit of the same; and |
42
(b) | hold in an interest-bearing suspense account any moneys received from the
Parent or on account of the Parent’s liability under this clause 17. |
17.7 | Deferral of Parent’s rights |
|
Until all amounts which may be or become payable by the Obligors under or in connection with
the Finance Documents have been irrevocably paid in full and unless the Agent otherwise
directs, the Parent will not exercise any rights which it may have by reason of performance
by it of its obligations under the Finance Documents or by reason of any amount being
payable, or liability arising, under this clause 17: |
(a) | to be indemnified by another Obligor; |
(b) | to claim any contribution from any other guarantor of any Obligor’s
obligations under the Finance Documents; |
(c) | to take the benefit (in whole or in part and whether by way of subrogation
or otherwise) of any rights of the Finance Parties under the Finance Documents or of
any other guarantee or security taken pursuant to, or in connection with, the Finance
Documents by any Finance Party; |
(d) | to bring legal or other proceedings for an order requiring any Obligor to
make any payment, or perform any obligation, in respect of which the Parent has given
a guarantee, undertaking or indemnity under clause 17 (Guarantee and Indemnity); |
43
(e) | to exercise any right of set-off against any other Obligor; and/or |
(f) | to claim or prove as a creditor of any other Obligor in competition with
any Finance Party. |
17.8 | Additional security |
|
This guarantee is in addition to and is not in any way prejudiced by any other guarantee or
security now or subsequently held by any Finance Party. |
44
DEFAULT
18 | Representations |
|
The Borrower makes and repeats the representations and warranties set out in this clause 18
to each Finance Party at the times specified in clause 18.28 (Times when representations are
made). |
||
18.1 | Status |
|
18.1.1 | Each Obligor is duly incorporated and validly existing under the laws of the jurisdiction
of its incorporation as a limited liability company or corporation and has no centre of main
interests, permanent establishment or place of business outside the jurisdiction in which it
is incorporated. |
|
18.1.2 | Each Obligor and each other Group Member has power and authority to carry on its business
as it is now being conducted and to own its property and other assets. |
|
18.2 | Binding obligations |
|
Subject to the Legal Reservations, the obligations expressed to be assumed by each Obligor in
each Finance Document and the Building Contract to which it is, or is to be, a party are or,
when entered into by it, will be legal, valid, binding and enforceable obligations and each
Security Document to which an Obligor is, or will be, a party, creates or will create the
Security Interests which that Security Document purports to create and those Security
Interests are or will be valid and effective. |
||
18.3 | Power and authority |
|
18.3.1 | Each Obligor has power to enter into, perform and deliver and comply with its obligations
under, and has taken all necessary action to authorise its entry into, each Finance Document
and the Building Contract to which it is or is to be a party. |
|
18.3.2 | No limitation on any Obligor’s powers to borrow, create security or give guarantees will be
exceeded as a result of any transaction under, or the entry into of, any Finance Document or
the Building Contract to which such Obligor is, or is to be, a party. |
|
18.4 | Non-conflict |
|
The entry into and performance by each Obligor of, and the transactions contemplated by, the
Finance Documents and the Building Contract and the granting of the Security Interests
purported to be created by the Security Documents do not and will not conflict with: |
(a) | any law or regulation applicable to any Obligor; |
45
(b) | the Constitutional Documents of any Obligor; or |
(c) | any agreement or other instrument binding upon any Obligor or any other
Group Member or its or any other Group Member’s assets, |
18.5 | Validity and admissibility in evidence |
|
18.5.1 | All authorisations required or desirable: |
(a) | to enable each Obligor lawfully to enter into, exercise its rights and
comply with its obligations under each Finance Document and the Building Contract to
which it is a party; |
(b) | to make each Finance Document and the Building Contract to which it is a
party admissible in evidence in its Relevant Jurisdiction; and |
(c) | to ensure that each of the Security Interests created under the Security
Documents has the priority and ranking contemplated by them, |
18.5.2 | All authorisations necessary for the conduct of the business, trade and ordinary activities
of each Obligor and each other Group Member have been obtained or effected and are in full
force and effect if failure to obtain or effect those authorisations might have a Material
Adverse Effect. |
|
18.6 | Governing law and enforcement |
|
18.6.1 | The choice of English law or any other applicable law as the governing law of any Finance
Document and the Building Contract will be recognised and enforced in each Obligor’s Relevant
Jurisdiction. |
|
18.6.2 | Any judgment obtained in England in relation to an Obligor will be recognised and enforced
in each Obligor’s Relevant Jurisdictions. |
|
18.7 | Information |
|
18.7.1 | Any Information is true and accurate in all material respects at the time it was given or
made. |
46
18.7.2 | There are no facts or circumstances or any other information which could make the
Information incomplete, untrue, inaccurate or misleading in any material respect. |
|
18.7.3 | The Information does not omit anything which could make the Information incomplete, untrue,
inaccurate or misleading in any material respect. |
|
18.7.4 | All opinions, projections, forecasts or expressions of intention contained in the
Information and the assumptions on which they are based have been arrived at after due and
careful enquiry and consideration and were believed to be reasonable by the person who
provided that Information as at the date it was given or made. |
|
18.7.5 | For the purposes of this clause 18.7, Information means: any information provided by any
Obligor or any other Group Member to any of the Finance Parties in connection with the
Finance Documents and the Building Contract or the transactions referred to in them. |
|
18.8 | Annual Financial Statements |
|
18.8.1 | The Annual Financial Statements, when prepared, will be in accordance with GAAP
consistently applied. |
|
18.8.2 | The Annual Financial Statements, when prepared, will give a true and fair view of the
financial condition and results of operations of the relevant Obligors and the Group
(consolidated in the case of the Group) during the relevant financial year. |
|
18.8.3 | There has been no material adverse change in its assets, business or financial condition
(or the assets, business or consolidated financial condition of the Group, in the case of the
Parent) since the date of the then current Annual Financial Statements or, as the case may
be, from the information disclosed to the Finance Parties in the statement provided by the
Obligors pursuant to Schedule 3, Part 1, paragraph 2(c). |
|
18.9 | Pari passu ranking |
|
Each Obligor’s payment obligations under the Finance Documents to which it is, or is to be, a
party rank at least pari passu with all its other present and future unsecured and
unsubordinated payment obligations, except for obligations mandatorily preferred by law
applying to companies generally. |
||
18.10 | Ranking and effectiveness of security |
|
Subject to the Legal Reservations and any filing, registration or notice requirements which
is referred to in any legal opinion delivered to the Agent under clause 4.1 (Initial
conditions precedent), the security created by the Security Documents has (or will have when
the Security Documents have been executed) the priority which it is expressed to have in the
Security Documents, the Charged Property is not subject to any Security Interest other than
Permitted
Security Interests and such security will constitute perfected security on the assets
described in the Security Documents. |
47
18.11 | No insolvency |
|
No corporate action, legal proceeding or other procedure or step described in clause 27.7
(Insolvency proceedings) or creditors’ process described in clause 27.8 (Creditors’ process)
has been taken or, to the knowledge of any Obligor, threatened in relation to a Group Member
and none of the circumstances described in clause 27.6 (Insolvency) applies to any Group
Member. |
||
18.12 | No filing or stamp taxes |
|
Under the laws of each Obligor’s Relevant Jurisdictions it is not necessary that any Finance
Document or the Building Contract to which it is, or is to be, party be filed, recorded or
enrolled with any court or other authority in that jurisdiction or that any stamp,
registration, notarial or similar Taxes or fees be paid on or in relation to any such Finance
Document or the Building Contract or the transactions contemplated by the Finance Documents
except any filing, recording or enrolling or any tax or fee payable in relation to any
Finance Document which is referred to in any legal opinion delivered to the Agent under
clause 4.1 (Initial conditions precedent) and which will be made or paid promptly after the
date of the relevant Finance Document. |
||
18.13 | Tax |
|
No Obligor is required to make any deduction for or on account of Tax from any payment it may
make under any Finance Document to which it is, or is to be, a party. |
||
18.14 | No Default |
|
18.14.1 | No Default is continuing or is reasonably likely to result from the making of any
Utilisation or the entry into, the performance of, or any transaction contemplated by, any
Finance Document or the Building Contract. |
|
18.14.2 | No other event or circumstance is outstanding which constitutes (or, with the expiry of a
grace period, the giving of notice, the making of any determination or any combination of any
of the foregoing, would constitute) a default or termination event (however described) under
any other agreement or instrument which is binding on any Obligor or any other Group Member
or to which any Obligor’s (or any other Group Member’s) assets are subject which might have a
Material Adverse Effect. |
|
18.15 | No proceedings pending or threatened |
|
No litigation, arbitration or administrative proceedings or investigations of, or before, any
court, arbitral body or agency which, if adversely determined, might reasonably be expected
to have a
Material Adverse Effect have (to the best of any Obligor’s knowledge and belief) been started
or threatened against any Obligor or any other Group Member. |
48
18.16 | No breach of laws |
|
18.16.1 | No Obligor or other Group Member has breached any law or regulation which might have a
Material Adverse Effect. |
|
18.16.2 | No labour dispute is current or, to the best of any Obligor’s knowledge and belief,
threatened against any Obligor or other Group Member which may have a Material Adverse
Effect. |
|
18.17 | Environmental matters |
|
18.17.1 | No Environmental Law applicable to any Fleet Vessel and/or any Obligor or other Group
Member has been violated in a manner or circumstances which might have, a Material Adverse
Effect. |
|
18.17.2 | All consents, licences and approvals required under such Environmental Laws have been
obtained and are currently in force. |
|
18.17.3 | No Environmental Claim has been made or threatened or is pending against any Group Member
or any Fleet Vessel where that claim might have a Material Adverse Effect and there has been
no Environmental Incident which has given, or might give, rise to such a claim. |
|
18.18 | Tax Compliance |
|
18.18.1 | No Obligor or other Group Member is materially overdue in the filing of any Tax returns or
overdue in the payment of any amount in respect of Tax. |
|
18.18.2 | No claims or investigations are being, or are reasonably likely to be, made or conducted
against any Obligor or other Group Member with respect to Taxes such that a liability of, or
claim against, any Obligor or other Group Member is reasonably likely to arise for an amount
for which evidence (satisfactory to the Majority Lenders) of adequate reserves have not been
provided and which might have a Material Adverse Effect. |
|
18.18.3 | Each Obligor is resident for Tax purposes only in the jurisdiction of its incorporation. |
|
18.18.4 | No Security Interest exists over all or any of the present or future assets of any Obligor
or other Group Member in breach of this Agreement. |
|
18.18.5 | No Obligor or other Group Member has any Financial Indebtedness outstanding in breach of
this Agreement. |
49
18.19 | Legal and beneficial ownership |
|
Each Obligor is the sole legal and beneficial owner of the respective assets over which it
purports to grant a Security Interest under the Security Documents. |
||
18.20 | Shares |
|
The shares of the Borrower are fully paid and not subject to any option to purchase or
similar rights. The Constitutional Documents of the Borrower do not and could not restrict
or inhibit any transfer of those shares on creation or enforcement of the Security Documents.
There are no agreements in force which provide for the issue or allotment of, or grant any
person the right to call for the issue or allotment of, any share or loan capital of the
Borrower (including any option or right of pre-emption or conversion). |
||
18.21 | Accounting Reference Date |
|
The financial year-end of each Obligor or other Group Member is the Accounting Reference
Date. |
||
18.22 | No adverse consequences |
|
18.22.1 | It is not necessary under the laws of the Relevant Jurisdictions of any Obligor: |
(a) | in order to enable any Finance Party to enforce its rights under any
Finance Document; or |
(b) | by reason of the execution of any Finance Document or the performance by
any Obligor of its obligations under any Finance Document to which it is, or is to
be, a party, |
18.22.2 | No Finance Party is or will be deemed to be resident, domiciled or carrying on business in
any Relevant Jurisdiction by reason only of the execution, performance and/or enforcement of
any Finance Document. |
18.23 | Copies of documents |
|
The copies of the Building Contract, the MOU, the Junior Security Documents and the
Constitutional Documents of the Obligors delivered to the Agent under clause 4 (Conditions of
Utilisation) will be true, complete and accurate copies of such documents and include all
amendments and supplements to them as at the time of such delivery and no other agreements or
arrangements exist between any of the parties to the Building
Contract which would materially affect the transactions or arrangements contemplated by the Building Contract or
modify or release the obligations of any party under the Building Contract. |
50
18.24 | No breach of Building Contract |
|
No Obligor nor (so far as the Obligors are aware) any other person is in breach of the
Building Contract to which it is a party nor has anything occurred which entitles or may
entitle any party to the Building Contract to rescind or terminate it or decline to perform
their obligations under it. |
18.25 | No immunity |
|
No Obligor or any of its assets is immune to any legal action or proceeding. |
||
18.26 | Ship status |
|
The Ship will on the first day of the Mortgage Period be: |
(a) | registered in the name of the Borrower through the relevant Registry as a
ship under the laws and flag of the relevant Flag State; |
||
(b) | operationally seaworthy and in every way fit for service; |
(c) | classed with the relevant Classification free of all requirements and
recommendations of the relevant Classification Society; and |
||
(d) | insured in the manner required by the Finance Documents. |
18.27 | Ship’s employment |
|
The Ship shall on the first day of the Mortgage Period be free of any charter commitment
which, if entered into after that date, would require approval under the Finance Documents. |
||
18.28 | Times when representations are made |
|
18.28.1 | All of the representations and warranties set out in this clause 18 (other than Ship
Representations) are deemed to be made on the dates of: |
(a) | this Agreement; |
||
(b) | the Utilisation Request; and |
||
(c) | the Utilisation. |
18.28.2 | The Repeating Representations are deemed to be made on the first day of each Interest
Period. |
|
18.28.3 | All of the Ship Representations are deemed to be made on the first day of the Mortgage
Period. |
51
18.28.4 | Each representation or warranty deemed to be made after the date of this Agreement shall
be deemed to be made by reference to the facts and circumstances then existing at the date
the representation or warranty is deemed to be made. |
|
19 | Information undertakings |
|
The Borrower undertakes that this clause 19 will be complied with throughout the Facility
Period. |
||
In this clause 19: |
19.1 | Financial statements |
|
19.1.1 | The Borrower shall supply to the Agent as soon as the same become available, but in any
event within 180 days after the end of each financial year: |
(a) | the audited consolidated financial statements of the Group for that
financial year; and |
(b) | the audited financial statements (consolidated if appropriate) of the
Parent and the Borrower for that financial year. |
19.1.2 | The Borrower shall supply to the Agent as soon as the same become available, but in any
event within 45 days after the end of each financial quarter of each of its financial years
the consolidated financial statements of the Group for that financial quarter. |
|
19.2 | Requirements as to financial statements |
19.2.1 | The Borrower shall procure that each set of Annual Financial Statements and Quarterly
Financial Statements includes a profit and loss account, a balance sheet and a cashflow
statement and that, in addition, each set of Annual Financial Statements shall be audited by
the Auditors. |
19.2.2 | Each set of financial statements delivered pursuant to clause 19.1 (Financial statements)
shall: |
(a) | be prepared in accordance with GAAP; |
(b) | give a true and fair view of (in the case of Annual Financial Statements
for any financial year), or fairly represent (in other cases), the financial
condition and operations of the Group or (as the case may be) the relevant Obligor as
at the date as at which those financial statements were drawn up; and |
52
(c) | in the case of annual audited financial statements, not be the subject of
any qualification in the Auditors’ opinion. |
19.2.3 | The Borrower shall procure that each set of financial statements delivered pursuant to
clause 19.1 (Financial statements) shall be prepared using GAAP unless, in relation to any
set of financial statements, the Borrower notifies the Agent that there has been a change in
GAAP or the Auditors deliver to the Agent a description of any change necessary for those
financial statements to reflect the GAAP. |
|
19.3 | Presentations |
|
Once in every financial year commencing with the 2011 financial year, and prior to 30
September of that year, or more frequently if requested to do so by the Agent if the Agent
reasonably suspects a Default is continuing or may have occurred or may occur, the Borrower
shall procure that at least two directors of the Parent (one of whom shall be the chief
financial officer) give a presentation to the Finance Parties about the on-going business and
financial performance of the Group and any other matter which a Finance Party may reasonably
request. |
||
19.4 | Year-end |
|
The Borrower shall procure that each financial year-end of each Obligor and each Group Member
falls on the Accounting Reference Date. |
||
19.5 | Information: miscellaneous |
|
The Borrower shall supply to the Agent: |
(a) | at the same time as they are dispatched, copies of all documents dispatched
by the Parent or any Obligors to its creditors generally (or any class of them); |
(b) | promptly upon becoming aware of them, the details of any litigation,
arbitration or administrative proceedings which are current, threatened or pending
against any Group Member, and which, if adversely determined, might have a Material
Adverse Effect; |
(c) | promptly, such information as the Agent may reasonably require about the
Charged Property and compliance of the Obligors with the terms of any Security
Documents; and |
(d) | promptly on request, such further information regarding the financial
condition, assets and operations of the Group and/or any Group Member as any Finance
Party through the Agent may reasonably request. |
53
19.6 | Notification of Default |
|
The Borrower shall notify the Agent of any Default (and the steps, if any, being taken to
remedy it) promptly upon any Obligor becoming aware of its occurrence (unless that Obligor is
aware that a notification has already been provided by another Obligor). |
||
19.7 | Sufficient copies |
|
The Borrower, if so requested by the Agent, shall deliver sufficient copies of each document
to be supplied under the Finance Documents to the Agent to distribute to each of the Lenders. |
||
19.8 | Use of websites |
|
19.8.1 | The Borrower may satisfy its obligation under this Agreement to deliver any information in
relation to those Lenders (the Website Lenders) who, by confirmation in writing to the
Borrower, accept this method of communication by posting this information onto an electronic
website designated by the Borrower and the Agent (the Designated Website) if: |
(a) | the Agent expressly agrees (after consultation with each of the Lenders)
that it will accept communication of the information by this method; |
(b) | both the Borrower and the Agent are aware of the address of and any
relevant password specifications for the Designated Website; and |
(c) | the information is in a format previously agreed between the Borrower and
the Agent. |
19.8.2 | The Agent shall supply each Website Lender with the address of and any relevant password
specifications for the Designated Website following designation of that website by the
Borrower and the Agent. |
19.8.3 | The Borrower shall promptly upon becoming aware of its occurrence notify the Agent if: |
(a) | the Designated Website cannot be accessed due to technical failure; |
||
(b) | the password specifications for the Designated Website change; |
(c) | any new information which is required to be provided under this Agreement
is posted onto the Designated Website; |
54
(d) | any existing information which has been provided under this Agreement and
posted onto the Designated Website is amended; or |
(e) | the Borrower becomes aware that the Designated Website or any information
posted onto the Designated Website is or has been infected by any electronic virus or
similar software. |
19.8.4 | Any Website Lender may request, through the Agent, one paper copy of any information
required to be provided under this Agreement which is posted onto the Designated Website.
The Borrower shall comply with any such request within ten Business Days. |
|
19.9 | “Know your customer” checks |
|
19.9.1 | If: |
(a) | the introduction of or any change in (or in the interpretation,
administration or application of) any law or regulation made after the date of this
Agreement; |
(b) | any change in the status of an Obligor or the composition of the
shareholders of an Obligor after the date of this Agreement; or |
(c) | a proposed assignment or transfer by a Lender of any of its rights and/or
obligations under this Agreement to a party that is not a Lender prior to such
assignment or transfer, |
19.9.2 | Each Finance Party shall promptly upon the request of the Agent or the Security Agent
supply, or procure the supply of, such documentation and other evidence as is reasonably
requested by
the Agent or the Security Agent (for itself) in order for it to carry out and be satisfied
with the results of all necessary “know your customer” or other similar checks under all
applicable laws and regulations pursuant to the transactions contemplated in the Finance
Documents. |
55
20 | General undertakings |
|
The Borrower undertakes that this clause 20 will be complied with throughout the Facility Period. |
||
20.1 | Use of proceeds |
|
The proceeds of Utilisation will be used exclusively for the purposes specified in clause 3
(Purpose). |
20.2 | Authorisations |
|
Each Obligor will promptly: |
(a) | obtain, comply with and do all that is necessary to maintain in full force
and effect; and |
||
(b) | supply certified copies to the Agent of, |
(i) | enable it to perform its obligations under the Finance Documents
and the Building Contract; |
(ii) | ensure the legality, validity, enforceability or admissibility in
evidence of any Finance Document or the Building Contract; and |
(iii) | carry on its business where failure to do so has, or is
reasonably likely to have, a Material Adverse Effect. |
20.3 | Compliance with laws |
|
Each Obligor and each other Group Member will comply in all respects with all laws and
regulations (including Environmental Laws) to which it may be subject. |
||
20.4 | Tax Compliance |
|
20.4.1 | Each Obligor and each Group Member shall pay and discharge all Taxes imposed upon it or its
assets within such time period as may be allowed by law without incurring penalties unless
and only to the extent that: |
(a) | such payment is being contested in good faith; |
56
(b) | adequate reserves are being maintained for those Taxes and the costs
required to contest them which have been disclosed in its latest financial statements
delivered to the Agent under clause 19.1 (Financial statements); and |
||
(c) | such payment can be lawfully withheld. |
20.4.2 | Except as approved by the Majority Lenders, each Obligor shall maintain its residence for
Tax purposes in the jurisdiction in which it is incorporated and ensure that it is not
resident for Tax purposes in any other jurisdiction. |
|
20.5 | Change of business |
|
Except as approved by the Majority Lenders, no substantial change will be made to the general
nature of the business of the Parent, the Obligors or the Group taken as a whole from that
carried on at the date of this Agreement. |
||
20.6 | Merger |
|
Except as approved by the Majority Lenders, no Obligor or other Group Member, will enter into
any amalgamation, demerger, merger, consolidation or corporate reconstruction. |
||
20.7 | Further assurance |
|
20.7.1 | Each Obligor shall promptly do all such acts or execute all such documents (including
assignments, transfers, mortgages, charges, notices and instructions) as the Agent may
reasonably specify (and in such form as the Agent may reasonably require): |
(a) | to perfect the Security Interests created or intended to be created by that
Obligor under or evidenced by the Security Documents (which may include the execution
of a mortgage, charge, assignment or other security over all or any of the assets
which are, or are intended to be, the subject of the Security Documents) or for the
exercise of any rights, powers and remedies of the Security Agent provided by or
pursuant to the Finance Documents or by law; |
(b) | to confer on the Security Agent Security Interests over any property and
assets of that Obligor located in any jurisdiction equivalent or similar to the
Security Interest intended to be conferred by or pursuant to the Security Documents; |
(c) | to facilitate the realisation of the assets which are, or are intended to
be, the subject of the Security Documents; and/or |
(d) | to facilitate the accession by a New Lender to any Security Document
following an assignment in accordance with clause 28.1 (Assignments and Transfers by
the Lenders). |
57
20.7.2 | Each Obligor shall take all such action as is available to it (including making all filings
and registrations) as may be necessary for the purpose of the creation, perfection,
protection or maintenance of any Security Interest conferred or intended to be conferred on
the Security Agent by or pursuant to the Finance Documents. |
|
20.8 | Negative pledge in respect of Charged Property |
|
Except for Permitted Security Interests, no Obligor will grant or allow to exist any Security
Interest over any Charged Property. |
||
20.9 | Environmental matters |
|
20.9.1 | The Agent will be notified as soon as reasonably practicable of any Environmental Claim
being made against any Group Member or any Fleet Vessel which, if successful to any extent,
might have a Material Adverse Effect and of any Environmental Incident which may give rise to
such a claim and will be kept regularly and promptly informed in reasonable detail of the
nature of, and response to, any such Environmental Incident and the defence to any such
claim. |
|
20.9.2 | Environmental Laws (and any consents, licences or approvals obtained under them) applicable
to Fleet Vessels will not be violated in a way which might have a Material Adverse Effect. |
|
21 | Dealings with Ship |
|
The Borrower undertakes that this clause 21 will be complied with in relation to the Ship
throughout the Mortgage Period. |
||
21.1 | Ship’s name and registration |
(a) | The Ship’s name shall only be changed after prior notice to the Agent. |
(b) | The Ship shall be permanently registered with the relevant Registry within
90 days of the date of the Mortgage and registered with the relevant Registry under
the laws of its Flag State. Except with approval of the Majority Lenders, the Ship
shall not be registered under any other flag or at any other port or fly any other
flag (other than that of its Flag State). If that registration is for a limited
period, it shall be renewed at least 45 days before the date it is due to expire and
the Agent shall be notified of that renewal at least 30 days before that date. |
(c) | Nothing will be done and no action will be omitted if that might result in
such registration being forfeited or imperilled or the Ship being required to be
registered under the laws of another state of registry. |
58
21.2 | Performance of Building Contract |
|
The Borrower shall duly and punctually observe and perform all the conditions and obligations
imposed on it by the Building Contract. |
21.3 | Arbitration under Building Contract |
|
The Borrower shall promptly notify the Agent: |
(a) | if either party begins an arbitration under the Building Contract; |
||
(b) | of the identity of the arbitrators; and |
||
(c) | of the conclusion of the arbitration and the terms of any arbitration
award. |
21.4 | Notification of certain events |
|
The Borrower shall notify the Agent immediately if either party cancels, rescinds, repudiates
or otherwise terminates the Building Contract (or purports to do so) or rejects the Ship (or
purports to do so) or if the Ship becomes a Total Loss or partial loss or is materially
damaged or if a dispute arises under the Building Contract. |
21.5 | Sale or other disposal of Ship |
|
Except with approval of the Majority Lenders: |
(a) | the Borrower shall not sell, or agree to, transfer, abandon or otherwise
dispose of the Ship or any share or interest in it or its rights under the Building
Contract; and |
(b) | the Beta Guarantor shall not sell, or agree to, transfer, abandon or
otherwise dispose of the Beta Ship or any share or interest in it. |
21.6 | Variation to Building Contract |
|
Except with approval of the Majority Lenders, the Building Contract, the MOU and, subject to
the Co-ordination Agreement, the Junior Security Documents shall not be varied. |
21.7 | Manager |
(a) | A manager of the Ship shall not be appointed unless such manager is an
Approved Technical Manager and the terms of its appointment and the terms of the
Technical Management Agreement are approved by the Agent (acting on the instructions
of the Majority Lenders) and that such Approved Technical Manager has delivered a
duly executed Manager’s Undertaking to the Security Agent. The Borrower shall not
agree to any change to the terms of appointment of an Approved Technical Manager or
the
Technical Management Agreement without the prior written approval of the Agent
(acting on the instructions of the Majority Lenders). |
59
(b) | If the appointment of the Approved Technical Manager shall at any time be
terminated, the Borrower shall immediately consult with the Agent (acting on the
instructions of the Majority Lenders) in order to appoint an alternative Approved
Technical Manager. |
(c) | The Borrower shall, if requested by the Agent (acting on the instructions
of the Majority Lenders), to take effect at any time following a date falling 12
months after the date of this Agreement change NOS Shipmanagement Pte Ltd to another
Approved Technical Manager on equivalent economic terms applicable to the technical
management agreement in force as at the Utilisation Date and the Borrower irrevocably
and unconditionally authorises the Agent to issue the notice referred to in paragraph
3.1(g) of the Technical Manager’s Undertaking (regarding the Approved Technical
Manager) to take effect at such time. |
21.8 | Copy of Mortgage on board |
|
A properly certified copy of the Mortgage shall be kept on board the Ship with its papers and
shown to anyone having business with the Ship which might create or imply any commitment or
Security Interest over or in respect of the Ship (other than a lien for crew’s wages and
salvage) and to any representative of the Agent or the Security Agent. |
21.9 | Notice of Mortgage |
|
A framed printed notice of the Mortgage shall be prominently displayed in the navigation room
and in the Master’s cabin of the Ship. The notice must be in plain type and read as follows: |
21.10 | Conveyance on default |
|
Where the Ship is (or is to be) sold in exercise of any power conferred by the Security
Documents, the Borrower shall, upon the Agent’s request, immediately execute such form of
transfer of title to the Ship as the Agent may require. |
60
21.11 | Chartering |
|
Except with approval of the Majority Lenders, the Borrower shall not enter into any charter
commitment for the Ship, which is: |
(a) | a bareboat or demise charter or passes possession and operational control
of the Ship to another person; |
||
(b) | capable of lasting more than 13 calendar months; |
(c) | on terms as to payment or amount of hire which are materially less
beneficial to it than the terms which at that time could reasonably be expected to be
obtained on the open market for vessels of the same age and type as the Ship under
charter commitments of a similar type and period; or |
||
(d) | to another Group Member or to TMT Co. Ltd. or any of its Subsidiaries. |
21.12 | Lay up |
|
Except with approval of the Majority Lenders, the Ship shall not be laid up or deactivated. |
||
21.13 | Sharing of Earnings |
|
Except with approval of the Majority Lenders, the Borrower shall not enter into any
arrangement under which its Earnings from the Ship may be shared with anyone else. |
||
21.14 | Payment of Earnings |
|
The Borrower’s Earnings from the Ship shall be paid in the way required by the General
Assignment. If any Earnings are held by brokers or other agents, they shall be paid to the
Security Agent, if it requires this after the Earnings have become payable to it under the
General Assignment. |
||
22 | Condition and operation of Ship |
|
The Borrower undertakes that this clause 22 will be complied with in relation to the Ship
throughout the Mortgage Period. |
||
22.1 | Defined terms |
|
In this clause 22 and in Schedule 3 (Conditions precedent): |
||
applicable code means any code or prescribed procedures required to be observed by the Ship
or the persons responsible for its operation under any applicable law (including but not
limited to those currently known as the ISM Code and the ISPS Code). |
61
applicable law means all laws and regulations applicable to vessels registered in the Ship’s
Flag State or which for any other reason apply to the Ship or to its condition or operation
at any relevant time. |
||
applicable operating certificate means any certificates or other document relating to the
Ship or its condition or operation required to be in force under any applicable law or any
applicable code. |
||
22.2 | Repair |
|
The Ship shall be kept in a good, safe and efficient state of repair. The quality of
workmanship and materials used to repair the Ship or replace any damaged, worn or lost parts
or equipment shall be sufficient to ensure that the Ship’s value is not reduced. |
||
22.3 | Modification |
|
Except with approval of the Majority Lenders, the structure, type or performance
characteristics of the Ship shall not be modified in a way which could or might materially
alter the Ship or materially reduce its value. |
||
22.4 | Removal of parts |
|
Except with approval of the Majority Lenders, no material part of the Ship or any equipment
shall be removed from the Ship if to do so would materially reduce its value (unless at the
same time it is replaced with equivalent parts or equipment owned by the Borrower free of any
Security Interest except under the Security Documents). |
||
22.5 | Third party owned equipment |
|
Except with approval of the Majority Lenders, equipment owned by a third party shall not be
installed on the Ship if it cannot be removed without risk of causing damage to the structure
or fabric of the Ship or incurring significant expense. |
||
22.6 | Maintenance of class; compliance with laws and codes |
|
The Ship’s class shall be the Classification. The Ship and every person who owns, operates
or manages the Ship shall comply with all applicable laws and the requirements of all
applicable codes. There shall be kept in force and on board the Ship or in such person’s
custody any applicable operating certificates which are required by applicable laws or
applicable codes to be carried on board the Ship or to be in such person’s custody. |
62
22.7 | Surveys |
|
The Ship shall be submitted to continuous surveys and any other surveys which are required
for it to maintain the Classification as its class. Copies of reports of those surveys shall
be provided promptly to the Agent if it so requests. |
||
22.8 | Inspection and notice of drydockings |
|
The Agent and/or surveyors or other persons appointed by it for such purpose shall (subject
to the proviso hereto) be allowed to board the Ship at all reasonable times to inspect it and
given all proper facilities needed for that purpose, provided that unless a Default has
occurred and is continuing the Agent and/or such surveyors and/or persons shall only be
allowed to board the Ship once in each period of 12 months. The Agent shall be given
reasonable advance notice of any intended drydocking of the Ship (whatever the purpose of
that drydocking). |
||
22.9 | Prevention of arrest |
|
All debts, damages, liabilities and outgoings which have given, or may give, rise to
maritime, statutory or possessory liens on, or claims enforceable against, the Ship, its
Earnings or Insurances shall be promptly paid and discharged. |
||
22.10 | Release from arrest |
|
The Ship, its Earnings and Insurances shall promptly be released from any arrest, detention,
attachment or levy, and any legal process against the Ship shall be promptly discharged, by
whatever action is required to achieve that release or discharge. |
||
22.11 | Information about Ship |
|
Not later than 30 days after the end of each Interest Period and also whenever the Agent
shall so request the same, the Agent shall promptly and within three Business Days of request
be given any information which it may reasonably require about the Ship or its employment,
position, use or operation, including details of towages and salvages, and copies of all its
charter commitments entered into by or on behalf of any Obligor and copies of any applicable
operating certificates. |
||
22.12 | Notification of certain events |
|
The Agent shall promptly be notified of: |
(a) | any damage to the Ship where the cost of the resulting repairs may exceed
the Major Casualty Amount; |
(b) | any occurrence which may result in the Ship becoming a Total Loss; |
63
(c) | any requisition of the Ship for hire; |
(d) | any Environmental Incident involving the Ship and Environmental Claim being
made in relation to such an incident; |
||
(e) | any withdrawal or threat to withdraw any applicable operating certificate; |
||
(f) | the issue of any operating certificate required under any applicable code; |
(g) | the receipt of notification that any application for such a certificate has
been refused; |
(h) | any requirement or recommendation made in relation to the Ship by any
insurer or the Classification Society or by any competent authority which is not, or
is unlikely to be, or cannot be, complied with in the manner or time required or
recommended; and |
(i) | any arrest or detention of the Ship or any exercise or purported exercise
of a lien or other claim on the Ship or its Earnings or Insurances. |
22.13 | Payment of outgoings |
|
All tolls, dues and other outgoings whatsoever in respect of the Ship and its Earnings and
Insurances shall be paid promptly. Proper accounting records shall be kept of the Ship and
its Earnings. |
||
22.14 | Evidence of payments |
|
The Agent shall be allowed proper and reasonable access to those accounting records when it
requests it and, when it requires it, shall be given satisfactory evidence that: |
(a) | the wages and allotments and the insurance and pension contributions of the
Ship’s crew are being promptly and regularly paid; |
(b) | all deductions from its crew’s wages in respect of any applicable Tax
liability are being properly accounted for; and |
(c) | the Ship’s master has no claim for disbursements other than those incurred
by him in the ordinary course of trading on the voyage then in progress. |
22.15 | Repairers’ liens |
|
Except with approval, the Ship shall not be put into any other person’s possession for work
to be done on the Ship if the cost of that work will exceed or is likely to exceed the Major
Casualty Amount unless that person gives the Security Agent a written undertaking in approved
terms not to exercise any lien on the Ship or its Earnings for any of the cost of such work. |
64
22.16 | Survey report |
|
Not later than 30 days after the Accounting Reference Date in each period of 12 months, and
as soon as reasonably practicable after the Agent requests it, the Agent shall be given a
report on the seaworthiness and/or safe operation of the Ship, from approved surveyors or
inspectors. If any recommendations are made in such a report they shall be complied with in
the way and by the time recommended in the report. |
22.17 | Lawful use |
|
The Ship shall not be employed: |
(a) | in any way or in any activity which is unlawful under international law or
the domestic laws of any relevant country; |
||
(b) | in carrying illicit or prohibited goods; |
(c) | in a way which may make it liable to be condemned by a prize court or
destroyed, seized or confiscated; or |
(d) | if there are hostilities in any part of the world (whether war has been
declared or not), in carrying contraband goods, |
and the persons responsible for the operation of the Ship shall take all necessary and proper
precautions to ensure that this does not happen including participation in industry or other
voluntary schemes available to the Ship and in which leading operators of ships operating
under the same flag or engaged in similar trades generally participate at the relevant time.
|
||
22.18 | War zones |
|
Except with approval, the Ship shall not enter or remain in any zone which has been declared
a war zone by any government entity or the Ship’s war risk insurers. If approval is granted
for it to do so, any requirements of the Agent and/or the Ship’s insurers necessary to ensure
that the Ship remains properly insured in accordance with the Finance Documents (including
any requirement for the payment of extra insurance premiums) shall be complied with. |
||
23 | Insurance |
|
The Borrower undertakes that this clause 23 shall be complied with in relation to the Ship
and its Insurances throughout the Mortgage Period. |
65
23.1 | Insurance terms |
|
In this clause 23: |
||
excess risks means the proportion (if any) of claims for general average, salvage and salvage
charges not recoverable under the hull and machinery insurances of a vessel in consequence of
the value at which the vessel is assessed for the purpose of such claims exceeding its
insured value. |
||
excess war risk P&I cover means cover for claims only in excess of amounts recoverable under
the usual war risk cover including (but not limited to) hull and machinery, crew and
protection and indemnity risks. |
||
hull cover means insurance cover against the risks identified in clause 23.2(a). |
||
minimum hull cover means an amount equal at the relevant time to 120% of the Loan. |
||
P&I risks means the usual risks (including liability for oil pollution, excess war risk P&I
cover) covered by a protection and indemnity association which is a member of the
International Group of protection and indemnity associations (or, if the International Group
ceases to exist, any other leading protection and indemnity association or other leading
provider of protection and indemnity insurance) (including, without limitation, the
proportion (if any) of any collision liability not covered under the terms of the hull
cover). |
23.2 | Coverage required |
|
The Ship shall at all times be insured: |
(a) | against fire and usual marine risks (including excess risks) and war risks
(including war protection and indemnity risks and terrorism risks) on an agreed value
basis, for at least its minimum hull cover and no less than its market value; |
(b) | against P&I risks for the highest amount then available in the insurance
market for vessels of similar age, size and type as the Ship (but, in relation to
liability for oil pollution, for an amount of not less than $1,000,000,000); |
(c) | against such other risks and matters which the Agent (if advised and
instructed by the Majority Lenders) notifies it that the Agent considers reasonable
for a prudent shipowner or operator to insure against at the time of that notice; and |
||
(d) | on terms which comply with the other provisions of this clause 23. |
23.3 | Placing of cover |
|
The insurance coverage required by clause 23.2 (Coverage required) shall be: |
(a) | in the name of the Borrower and (in the case of the Ship’s hull cover) no
other person (other than the Security Agent if required by it) (unless such other
person is approved
and, if so required by the Agent, has duly executed and delivered a first priority
assignment of its interest in the Ship’s Insurances to the Security Agent in an
approved form and provided such supporting documents and opinions in relation to that
assignment as the Agent requires); |
66
(b) | if the Agent (if so instructed by the Majority Lenders) so requests, in the
joint names of the Borrower and the Security Agent (and, to the extent reasonably
practicable in the insurance market, without liability on the part of the Security
Agent for premiums or calls); |
||
(c) | in dollars or another approved currency; |
(d) | arranged through approved brokers or direct with approved insurers or
protection and indemnity or war risks associations; and |
||
(e) | on approved terms and with approved insurers or associations. |
23.4 | Deductibles |
|
The aggregate amount of any excess or deductible under the Ship’s hull cover shall not exceed
an approved amount. |
23.5 | Mortgagee’s insurance |
|
The Borrower shall promptly reimburse to the Agent the cost (as conclusively certified by the
Agent) of taking out and keeping in force in respect of the Ship on approved terms, or in
considering or making claims under: |
(a) | a mortgagee’s interest insurance and a mortgagee’s additional perils
(pollution risks) cover for the benefit of the Finance Parties for an amount up to
110% of the Loan; and |
(b) | any other insurance cover which the Agent (if so instructed by the Majority
Lenders) reasonably requires in respect of any Finance Party’s interests and
potential liabilities (whether as mortgagee of the Ship or beneficiary of the
Security Documents). |
23.6 | Fleet liens, set off and cancellations |
|
If the Ship’s hull cover also insures other vessels, the Security Agent shall either be given
an undertaking in approved terms by the brokers or (if such cover is not placed through
brokers or the brokers do not, under any applicable laws or insurance terms, have such rights
of set off and cancellation) the relevant insurers that the brokers or (if relevant) the
insurers will not: |
(a) | set off against any claims in respect of the Ship any premiums due in
respect of any of such other vessels insured; or |
67
(b) | cancel that cover because of non-payment of premiums in respect of such
other vessels, |
or the Borrower shall ensure that hull cover for the Ship is provided under a separate policy
from any other vessels. |
||
23.7 | Payment of premiums |
|
All premiums, calls, contributions or other sums payable in respect of the Insurances shall
be paid punctually and the Agent shall be provided with all relevant receipts or other
evidence of payment upon request. |
||
23.8 | Details of proposed renewal of Insurances |
|
At least 14 days before any of the Insurances are due to expire, the Agent shall be notified
of the names of the brokers, insurers and associations proposed to be used for the renewal of
such Insurances and the amounts, risks and terms in, against and on which the Insurances are
proposed to be renewed. |
||
23.9 | Instructions for renewal |
|
At least seven days before any of the Insurances are due to expire, instructions shall be
given by the Borrower to brokers, insurers and associations for them to be renewed or
replaced on or before their expiry. |
||
23.10 | Confirmation of renewal |
|
The Insurances shall be renewed upon their expiry in a manner and on terms which comply with
this clause 23 and confirmation of such renewal given by approved brokers or insurers to the
Agent at least seven days (or such shorter period as may be approved) before such expiry. |
||
23.11 | P&I guarantees |
|
Any guarantee or undertaking required by any protection and indemnity or war risks
association in relation to the Ship shall be provided when required by the association. |
||
23.12 | Insurance documents |
|
The Agent shall be provided with pro forma copies of all insurance policies and other
documentation issued by brokers, insurers and associations in connection with the Insurances
as soon as they are available after they have been placed or renewed and all insurance
policies and other documents relating to the Insurances shall be deposited with any approved
brokers or (if not deposited with approved brokers) the Agent or some other approved person.
The Agent shall have no obligation to monitor the Borrower’s obligations with respect to the
Insurances or to review the insurance policies and other documentation from time to time. |
68
23.13 | Letters of undertaking |
|
Unless otherwise approved where the Agent (if advised and instructed by the Majority Lenders)
is satisfied that equivalent protection is afforded by the terms of the relevant Insurances
and/or any applicable law and/or a letter of undertaking provided by another person, on each
placing or renewal of the Insurances, the Agent shall be provided promptly with letters of
undertaking in an approved form (having regard to general insurance market practice and law
at the time of issue of such letter of undertaking) from the relevant brokers, insurers and
associations. |
||
23.14 | Insurance Notices and Loss Payable Clauses |
|
The interest of the Security Agent as assignee of the Insurances shall be endorsed on all
insurance policies and other documents by the incorporation of a Loss Payable Clause and an
Insurance Notice in respect of the Ship and its Insurances signed by the Borrower and, unless
otherwise approved, each other person assured under the relevant cover (other than the
Security Agent if it is itself an assured). |
||
23.15 | Insurance correspondence |
|
If so required by the Agent, the Agent shall promptly be provided with copies of all written
communications between the assureds and brokers, insurers and associations relating to any of
the Insurances as soon as they are available. |
||
23.16 | Qualifications and exclusions |
|
All requirements applicable to the Insurances shall be complied with and the Insurances shall
only be subject to approved exclusions or qualifications. |
||
23.17 | Independent report |
|
If the Agent asks the Borrower for a detailed report from an approved independent firm of
marine insurance brokers giving their opinion on the adequacy of the Insurances then the
Agent shall be provided promptly with such a report at no cost to the Agent or (if the Agent
obtains such a report itself) the Borrower shall reimburse the Agent for the cost of
obtaining that report. |
||
23.18 | Collection of claims |
|
All documents and other information and all assistance required by the Agent to assist it
and/or the Security Agent in trying to collect or recover any claims under the Ship’s
Insurances shall be provided promptly. |
69
23.19 | Employment of Ship |
|
The Ship shall only be employed or operated in conformity with the terms of the Insurances
(including any express or implied warranties) and not in any other way (unless the insurers
have consented and any additional requirements of the insurers have been satisfied). |
||
23.20 | Declarations and returns |
|
If any of the Insurances are on terms that require a declaration, certificate or other
document to be made or filed before the Ship sails to, or operates within, an area, those
terms shall be complied with within the time and in the manner required by those Insurances. |
||
23.21 | Application of recoveries |
|
All sums paid under the Insurances to anyone other than the Security Agent shall be applied
in repairing the damage and/or in discharging the liability in respect of which they have
been paid except to the extent that the repairs have already been paid for and/or the
liability already discharged. |
||
23.22 | Settlement of claims |
|
Any claim under the Insurances for a Total Loss or Major Casualty shall only be settled,
compromised or abandoned with prior approval. |
||
23.23 | Change in insurance requirements |
|
If the Agent gives notice to the Borrower to change the terms and requirements of this clause
23 (which the Agent may only do, in such manner as it considers appropriate, as a result in
changes of circumstances or practice after the date of this Agreement), this clause 23 shall
be modified in the manner so notified by the Agent on the date 14 days after such notice from
the Agent is received. |
||
24 | Valuations |
|
The Borrower undertakes that this clause 24 will be complied with throughout any Mortgage
Period. |
||
24.1 | Valuation of assets |
|
For the purpose of the Finance Documents, the value at any time of the Ship will be its value
as most recently determined in accordance with this clause 24. |
70
24.2 | Valuation frequency |
|
The Ship shall be valued in accordance with this clause 24, and such valuation shall be
delivered to the Agent, not later than 15 days after the end of each Interest Period and at
any other such time as may be required by the Agent. |
||
24.3 | Expenses of valuation |
|
The Borrower shall bear, and reimburse to the Agent where incurred by the Agent, all costs
and expenses of providing such a valuation. |
||
24.4 | Valuations procedure |
|
The value of the Ship shall be determined in accordance with, and by valuers approved and
appointed in accordance with, this clause 24. |
||
24.5 | Currency of valuation |
|
Valuations shall be provided by valuers in dollars or, if a valuer is of the view that the
relevant type of vessel is generally bought and sold in another currency, in that other
currency. If a valuation is provided in another currency, for the purposes of this Agreement
it shall be converted into dollars at the Agent’s spot rate of exchange for the purchase of
dollars with that other currency as at the date to which the valuation relates. |
||
24.6 | Basis of valuation |
|
Each valuation will be addressed to the Agent in its capacity as such and made: |
(a) | without physical inspection (unless required by the Agent); |
(b) | on the basis of a sale for prompt delivery for a price payable in full in
cash on delivery at arm’s length on normal commercial terms between a willing buyer
and a willing seller; and |
(c) | without taking into account the benefit (but taking into account the
burden) of any charter commitment. |
24.7 | Information required for valuation |
|
The Borrower shall promptly provide to the Agent and any such valuer any information which
they reasonably require for the purposes of providing such a valuation. |
71
24.8 | Approval of valuers |
|
All valuers must have been approved (and as at the date of this Agreement, each of Clarksons,
Fearnleys, Xxxxxxx, Xxxxxx and Xxxxx, Braemar Seascope and Xxxxx Xxxxxxxx Salles have been
approved). The Agent may from time to time notify the Borrower of approval of any other
independent ship brokers as valuers for the purposes of this clause 24. The Agent shall
respond, if advised and instructed by the Majority Lenders, to any request by the Borrower
for approval of a broker nominated by the Borrower. The Agent (if so instructed by the
Majority Lenders) may at any time by notice to the Borrower withdraw any previous approval of
a valuer for the purposes of future valuations. That valuer may not then be appointed to
provide valuations unless it is once more approved. |
||
25 | Bank accounts |
|
The Borrower undertakes that this clause 25 will be complied with throughout the Facility Period.
|
||
25.1 | Earnings Account |
|
25.1.1 | The Borrower shall be the holder of one or more Accounts with the Earnings Account Bank
which is designated as an “Earnings Account” for the purposes of the Finance Documents. |
|
25.1.2 | The Earnings of the Ship and all moneys payable to the Borrower under the Insurances shall
be paid by the persons from whom they are due to an Earnings Account unless required to be
paid to the Security Agent under the Finance Documents. |
|
25.1.3 | The Borrower shall not withdraw amounts standing to the credit of an Earnings Account
except as permitted by clause 25.1.4. |
|
25.1.4 | If there is no continuing Event of Default, the Borrower may, during the Facility Period,
withdraw the following amounts from an Earnings Account and in the following order of
priority: |
(a) | payments then due to Finance Parties under the Finance Documents (other
than payments due in respect of a prepayment); |
(b) | payments on account of any Manager’s fees due under any management
agreement in respect of the Ship; |
(c) | payments of the proper costs and expenses of insuring, repairing, operating
and maintaining the Ship; |
(d) | payments then due to the Builder under the Building Contract Addendum on
account of interest with respect to Deferred Instalment I only; and |
72
(e) | subject to the amounts standing to the credit of the Alpha Debt Service
Reserve Account being at least $7,500,000 following the withdrawal pursuant to clause
25.2.2 (Alpha Debt Service Reserve Account), the Borrower confirming to the Agent in
writing that no Default has occurred and is continuing and to the Agent (acting on
the instructions of the Majority Lenders) being satisfied that (i) no payment
referred to in paragraphs (a) to (d) above will need to be paid prior to receipt of
any further Earnings and (ii) there is an amount agreed with the Agent (acting on the
instructions of the Majority Lenders) standing to the credit of the Earnings Account,
by way of reserve, to enable the Borrower to meet anticipated expenses relating to
the Ship for the next 12 months, including, without limitation, in respect of dry
docking expenses and operating expenses for any anticipated periods of off hire,
lay-up or unemployment, which are not covered by loss of hire insurances, payments to
Xxxx in accordance with the MOU. |
25.2 | Alpha Debt Service Reserve Account |
|
25.2.1 | The Borrower shall be the holder of an Account denominated in dollars with the Debt Service
Reserve Account Bank which is designated as the “Alpha Debt Service Reserve Account” for the
purposes of the Finance Documents. |
|
25.2.2 | The Borrower shall pay to the credit of the Alpha Debt Service Reserve Account amounts
received into the Earnings Account, up to an amount of $7,500,000 at any time when, from time
to time, each of the payments required under clauses 25.1.4(a) to (c) have been met, subject
to the Agent (acting on the instructions of the Majority Lenders) being satisfied that it is
likely that no payment referred to in clauses 25.1.4(a) to (c) will need to be paid prior to
receipt of any further Earnings, which amount shall, unless otherwise approved or withdrawn
in accordance with clause 25.2.3 below, remain standing to the credit of the Alpha Debt
Service Reserve Account throughout the duration of the Facility Period. |
|
25.2.3 | The Borrower may, with the prior consent of the Agent (acting on the instructions of the
Majority Lenders), utilise up to $2,500,000 of the balance of the Alpha Debt Service Reserve
Account, which consent shall not be unreasonably withheld in the case of a withdrawal to make
a payment required under clauses 25.1.4(a) to 25.1.4(c). |
|
25.3 | Other provisions |
|
25.3.1 | An Account may only be designated for the purposes described in this clause 25 if: |
(a) | such designation is made in writing by the Agent and acknowledged by the
Borrower or, as the case may be, the Parent and specifies the name and address of the
Account Bank and the number and any designation or other reference attributed to the
Account; |
(b) | an Account Security has been duly executed and delivered by the Borrower
or, as the case may be, the Parent in favour of the Security Agent; |
73
(c) | any notice required by the Account Security to be given to an Account Bank
has been given to, and acknowledged by, the Account Bank in the form required by the
relevant Account Security; and |
(d) | the Agent, or its duly authorised representative, has received such
documents and evidence it may require in relation to the Account and the Account
Security including documents and evidence of the type referred to in Schedule 3 in
relation to the Account and the relevant Account Security. |
25.3.2 | The rates of payment of interest and other terms regulating any Account will be a matter of
separate agreement between the Borrower or, as the case may be, the Parent and the relevant
Account Bank. If an Account is a fixed term deposit account, the Borrower or, as the case
may be, the Parent may select the terms of deposits until the relevant Account Security has
become enforceable and the Security Agent directs otherwise. |
|
25.3.3 | The Borrower or, as the case may be, the Parent shall not close any Account or alter the
terms of any Account from those in force at the time it is designated for the purposes of
this clause 25 or waive any of its rights in relation to an Account except with approval of
all Lenders. |
|
25.3.4 | The Borrower or, as the case may be, the Parent shall deposit with the Security Agent all
certificates of deposit, receipts or other instruments or securities relating to any Account,
notify the Security Agent of any claim or notice relating to an Account from any other party
and provide the Agent with any other information it may request concerning any Account. |
|
25.3.5 | Each Finance Party agrees that if it is an Account Bank in respect of an Account then there
will be no restrictions on creating a Security Interest over that Account as contemplated by
this Agreement and it shall not (except with the approval of the Majority Lenders) exercise
any right of combination, consolidation or set-off which it may have in respect of that
Account in a manner adverse to the rights of the other Finance Parties. |
|
25.3.6 | The Borrower shall procure that each Account Bank delivers account statements to the Agent
at such intervals as the Agent may request in writing to the Borrower. |
|
26 | Business restrictions |
|
Except as otherwise approved by the Majority Lenders the Borrower and the Parent undertake
that this clause 26 will be complied with by the Borrower, the Beta Guarantor and the Parent
throughout the Facility Period. |
74
26.1 | General negative pledge |
|
26.1.1 | No Obligor shall permit any Security Interest to exist, arise or be created or extended
over all or any part of its assets except for: |
(a) | those granted or expressed to be granted by any of the Security Documents
and the Junior Security Documents; |
||
(b) | in relation to the Ship, Permitted Maritime Liens; |
(c) | in relation to the Beta Ship, Permitted Maritime Liens (as defined in the
Beta Facility Agreement). |
26.1.2 | (Without prejudice to clauses 26.2 (Financial Indebtedness) and 26.6 (Disposals)), no
Obligor shall: |
(a) | sell, transfer or otherwise dispose of any of its assets on terms whereby
that asset is or may be leased to, or re-acquired by, any other Group Member other
than pursuant to disposals permitted under clause 26.6 (Disposals); |
(b) | sell, transfer, factor or otherwise dispose of any of its receivables on
recourse terms (except for the discounting of bills or notes in the ordinary course
of business); |
(c) | enter into any arrangement under which money or the benefit of a bank or
other account may be applied, set-off or made subject to a combination of accounts;
or |
||
(d) | enter into any other preferential arrangement having a similar effect, |
26.2 | Financial Indebtedness |
|
No Obligor shall incur or permit to exist, any Financial Indebtedness owed by it to anyone
else except: |
(a) | Financial Indebtedness incurred under the Finance Documents; |
||
(b) | Financial Indebtedness incurred under the Building Contract Addendum; |
||
(c) | Financial Indebtedness incurred pursuant to the Beta Facility Agreement; |
||
(d) | Financial Indebtedness incurred under the Beta Building Contract Addendum; |
||
(e) | Financial Indebtedness permitted under clause 26.3 (Guarantees); and |
||
(f) | Financial Indebtedness permitted under clause 26.4 (Loans and credit). |
75
26.3 | Guarantees |
|
No Obligor shall give or permit to exist, any guarantee by it in respect of indebtedness of
any person or allow any of its indebtedness to be guaranteed by anyone else except guarantees
pursuant to this Agreement, the Building Contract Addendum, the Beta Facility Agreement or
the Beta Building Contract Addendum or in favour of trade creditors of the Borrower or the
Beta Guarantor given in the ordinary course of its business or as approved by the Agent
(acting on the instructions of the Majority Lenders). |
26.4 | Loans and credit |
|
No Obligor shall make, grant or permit to exist any loans or any credit by it to anyone else
other than trade credit granted by the Borrower or the Beta Guarantor to its customers on
normal commercial terms in the ordinary course of its trading activities. |
26.5 | Bank accounts and other financial transactions |
|
No Obligor shall: |
(a) | maintain any current or deposit account with a bank or financial
institution except for the deposit of money, operation of current accounts and the
conduct of electronic banking operations with Lenders; |
(b) | hold cash in any account (other than with the Agent, a Lender or any other
bank approved by the Lenders) over or in respect of which any set-off, combination of
accounts, netting or Security Interest exists except as permitted by clause 26.1
(General negative pledge); or |
(c) | be party to any banking or financial transaction, whether on or off balance
sheet, that is not expressly permitted under this clause 26 (Business restrictions). |
26.6 | Disposals |
|
No Obligor shall enter into a single transaction or a series of transactions, whether related
or not and whether voluntarily or involuntarily, to dispose of any asset except for any of
the following disposals so long as they are not prohibited by any other provision of the
Finance Documents: |
(a) | disposals of obsolete assets, or assets which are no longer required for
the purpose of the business of the Borrower, the Beta Guarantor or the Parent (other
than the Ship or the Beta Ship), in each case for cash on normal commercial terms and
on an arm’s length basis; |
(b) | dealings with trade creditors with respect to book debts in the ordinary
course of trading; and |
76
(c) | the application of cash or cash equivalents in the acquisition of assets or
services in the ordinary course of its business. |
26.7 | Contracts and arrangements with Affiliates |
|
No Obligor shall be party to any arrangement or contract with any of its Affiliates, TMT Co.
Ltd. or any of its Subsidiaries unless such arrangement or contract is on an arm’s length
basis or is otherwise disclosed pursuant to the MOU. |
26.8 | Subsidiaries |
|
No Obligor shall establish or acquire a company or other entity which would be or become a
Subsidiary or a Group Member. |
26.9 | Acquisitions and investments |
(a) | acquisitions of assets in the ordinary course of business (not being new
businesses or vessels); |
||
(b) | the incurrence of liabilities in the ordinary course of its business; |
||
(c) | pursuant to any Finance Documents to which it is party; |
(d) | any acquisition pursuant to a disposal permitted under clause 26.6
(Disposals); or |
(e) | investments by the Parent in the equity or share capital of another Group
Member. |
26.10 | Reduction of capital |
|
No Obligor shall redeem or purchase or otherwise reduce any of its equity or any other share
capital or any warrants or any uncalled or unpaid liability in respect of any of them or
reduce the amount (if any) for the time being standing to the credit of its share premium
account or capital redemption or other undistributable reserve in any manner. |
26.11 | Increase in capital |
|
No Obligor (other than the Parent) shall issue shares or other equity interests to anyone who
is not a wholly-owned Subsidiary of the Parent. |
77
26.12 | Distributions and other payments |
|
No Obligor shall: |
(a) | declare or pay (including by way of set-off, combination of accounts or
otherwise) any dividend or redeem or make any other distribution or payment (whether
in cash or in specie), including any interest and/or unpaid dividends, in respect of
its equity or any other share capital or any warrants for the time being in issue; or |
(b) | make any payment (including by way of set-off, combination of accounts or
otherwise) by way of interest, or repayment, redemption, purchase or other payment,
in respect of any shareholder loan, loan stock or similar instrument, |
27 | Events of Default |
|
Each of the events or circumstances set out in clauses 27.1 to 27.21 is an Event of Default. |
||
27.1 | Non-payment |
|
An Obligor does not pay on the due date any amount payable pursuant to a Finance Document at
the place at and in the currency in which it is expressed to be payable unless such failure
is solely the result of any bank or financial institution not promptly remitting a payment as
instructed by that Obligor and if that Obligor has taken all reasonable steps to cause such
payment to be made, the period for the remedy of such payment failure shall be extended by
five Business Days. |
||
27.2 | Insurance |
|
27.2.1 | The Insurances of the Ship are not placed and kept in force in the manner required by
clause 23 (Insurance). |
|
27.2.2 | Any insurer either: |
(a) | cancels any such Insurances; or |
(b) | disclaims liability under them by reason of any mis-statement or failure or
default by any person. |
78
27.3 | Other obligations |
|
27.3.1 | An Obligor does not comply with any provision of the Finance Documents (other than those
referred to in clauses 27.1 (Non-payment) and 27.2 (Insurance)). |
|
27.3.2 | No Event of Default under clause 27.3.1 above will occur if the Agent considers that the
failure to comply is capable of remedy and the failure is remedied within ten Business Days
of the earlier of (a) the Agent giving notice to the Borrower or (b) the Borrower becoming
aware of the failure to comply. |
|
27.4 | Misrepresentation |
|
Any representation or statement made or deemed to be made by an Obligor in the Finance
Documents or any other document delivered by or on behalf of any Obligor under or in
connection with any Finance Document is or proves to have been incorrect or misleading in any
material respect when made or deemed to be made. |
||
27.5 | Cross default |
|
27.5.1 | Any Financial Indebtedness of any Group Member is not paid when due nor within any
originally applicable grace period. |
|
27.5.2 | Any Financial Indebtedness of any Group Member is declared to be or otherwise becomes due
and payable prior to its specified maturity as a result of an event of default (however
described). |
|
27.5.3 | Any commitment for any Financial Indebtedness of any Group Member is cancelled or suspended
by a creditor of that Group Member as a result of an event of default (however described). |
|
27.5.4 | The counterparty to a Treasury Transaction entered into by any Group Member becomes
entitled to terminate that Treasury Transaction early by reason of an event of default
(however described). |
|
27.5.5 | Any creditor of any Group Member becomes entitled to declare any Financial Indebtedness of
that Group Member due and payable prior to its specified maturity as a result of an event of
default (however described). |
|
27.6 | Insolvency |
|
27.6.1 | A Group Member is unable or admits inability to pay its debts as they fall due, suspends
making payments on any of its debts or, by reason of actual or anticipated financial
difficulties, commences negotiations with one or more of its creditors with a view to
rescheduling any of its indebtedness. |
79
27.6.2 | The value of the assets of any Group Member is less than its liabilities (taking into
account contingent and prospective liabilities). |
|
27.6.3 | A moratorium is declared in respect of any indebtedness of any Group Member. If a
moratorium occurs, the ending of the moratorium will not remedy any Event of Default caused
by that moratorium. |
|
27.7 | Insolvency proceedings |
|
27.7.1 | Any corporate action, legal proceedings or other procedure or step is taken in relation to: |
(a) | the suspension of payments, a moratorium of any indebtedness, winding-up,
dissolution, administration or reorganisation (by way of voluntary arrangement,
scheme of arrangement or otherwise) of any Group Member other than a solvent
liquidation of any Group Member which is not an Obligor; |
(b) | a composition, compromise, assignment or arrangement with any creditor of
any Group Member; |
(c) | the appointment of a liquidator (other than in respect of an approved
solvent liquidation of a Group Member which is not an Obligor), receiver,
administrator, administrative receiver, compulsory manager or other similar officer
in respect of any Group Member or any of its assets (including the directors of any
Group Member requesting a person to appoint any such officer in relation to it or any
of its assets); or |
||
(d) | enforcement of any Security Interest over any assets of any Group Member, |
27.7.2 | Clause 27.7.1 shall not apply to any winding-up petition (or analogous procedure or step)
which is frivolous or vexatious and is discharged, stayed or dismissed within 14 days of
commencement or, if earlier, the date on which it is advertised. |
|
27.8 | Creditors’ process |
|
27.8.1 | Any expropriation, attachment, sequestration, distress, execution or analogous process
affects any asset or assets of any Obligor and is not discharged within 14 days. |
|
27.8.2 | Any judgment or order for an amount is made against any Obligor and is not stayed or
complied with within 14 days. |
80
27.9 | Unlawfulness and invalidity |
|
27.9.1 | It is or becomes unlawful for an Obligor to perform any of its obligations under the
Finance Documents or any Security Interest created or expressed to be created or evidenced by
the Security Documents ceases to be effective. |
|
27.9.2 | Any obligation or obligations of any Obligor under any Finance Documents are not (subject
to the Legal Reservations) or cease to be legal, valid, binding or enforceable and the
cessation individually or cumulatively materially and adversely affects the interests of the
Lenders under the Finance Documents. |
|
27.9.3 | Any Finance Document or any Security Interest created or expressed to be created or
evidenced by the Security Documents ceases to be in full force and effect or is alleged by a
party to it (other than a Finance Party) to be ineffective for any reason. |
|
27.9.4 | Any Security Document does not create legal, valid, binding and enforceable security over
the assets charged under that Security Document or the ranking or priority of such security
is adversely affected. |
|
27.10 | Cessation of business |
|
Any Obligor suspends or ceases to carry on (or threatens to suspend or cease to carry on) all
or a material part of its business. |
||
27.11 | Change of Control |
|
It appears likely to any of the Finance Parties that there has been a Change of Control
without the prior approval of the Agent. |
||
27.12 | Expropriation |
|
The authority or ability of any Obligor to conduct its business is limited or wholly or
substantially curtailed by any seizure, expropriation, nationalisation, intervention,
restriction or other action by or on behalf of any governmental, regulatory or other
authority or other person in relation to any Obligor or any of its assets. |
||
27.13 | Repudiation and rescission of Finance Documents |
|
An Obligor (or any other relevant party) repudiates or purports to repudiate a Finance
Document or evidences an intention to rescind or purports to rescind a Finance Document. |
81
27.14 | Litigation |
|
Any litigation, alternative dispute resolution, arbitration or administrative proceeding is
taking place, or threatened against any Group Member or any of its assets, rights or revenues
which, if adversely determined, might have a Material Adverse Effect. |
||
27.15 | Material Adverse Effect |
|
Any Environmental Incident or other event or circumstance or series of events (including any
change of law) occurs which the Majority Lenders believe has, or is reasonably likely to
have, a Material Adverse Effect. |
||
27.16 | Security enforceable |
|
Any Security Interest (other than a Permitted Maritime Lien) in respect of Charged Property
becomes enforceable. |
||
27.17 | Arrest of Ship |
|
The Ship is arrested, confiscated, seized, taken in execution, impounded, forfeited, detained
in exercise or purported exercise of any possessory lien or other claim and the Borrower
fails to procure the release of the Ship within a period of seven days thereafter (or such
longer period as may be approved). |
||
27.18 | Ship registration |
|
Except with approval, the registration of the Ship under the laws and flag of its Flag State
is cancelled or terminated or, where applicable, not renewed or, if the Ship is only
provisionally registered on the date of the Mortgage, the Ship is not permanently registered
under such laws within 90 days of such date or such longer period as may be permitted by the
Flag State not exceeding 180 days in total. |
||
27.19 | Political risk |
|
The Flag State or any Relevant Jurisdiction of an Obligor becomes involved in hostilities or
civil war or there is a seizure of power in the Flag State or any such Relevant Jurisdiction
by unconstitutional means if, in any such case, such event or circumstance, in the reasonable
opinion of the Majority Lenders, has or is reasonably likely to have, a Material Adverse
Effect and, within 14 days of notice from the Agent to do so, such action as the Agent (as
advised and instructed by the Majority Lenders) may require to ensure that such event or
circumstance will not have such an effect has not been taken by the Borrower. |
82
27.20 | Beta Facility Agreement |
|
An Event of Default (as defined in the Beta Facility Agreement) occurs under the Beta
Facility Agreement. |
||
27.21 | Building Contract Addendum and Beta Building Contract Addendum |
(a) | An Event of Default (as defined in the Building Contract Addendum) occurs
under the Building Contract Addendum. |
(b) | An Event of Default (as defined in the Beta Building Contract Addendum)
occurs under the Beta Building Contract Addendum. |
27.22 | Acceleration |
|
On and at any time after the occurrence of an Event of Default which is continuing the Agent
may, and shall if so directed by the Majority Lenders, by notice to the Borrower: |
(a) | cancel the Total Commitments at which time they shall immediately be
cancelled; and/or |
(b) | declare that all or part of the Loan, together with accrued interest, and
all other amounts accrued or outstanding under the Finance Documents be immediately
due and payable, at which time they shall become immediately due and payable; and/or |
(c) | declare that all or part of the Loan be payable on demand, at which time it
shall immediately become payable on demand by the Agent on the instructions of the
Majority Lenders; and/or |
||
(d) | declare that no withdrawals be made from any Account; and/or |
(e) | exercise or direct the Security Agent and/or any other beneficiary of the
Security Documents to exercise any or all of its rights, remedies, powers or
discretions under the Finance Documents. |
83
28 | Changes to the Lenders |
|
28.1 | Assignments and transfers by the Lenders |
|
Subject to this clause 28, a Lender (the Existing Lender) may assign any of its rights to any
individual, corporation, institution, trust, fund or other entity at the complete discretion
of the Existing Lender (the New Lender). |
||
28.2 | Conditions of assignment |
|
28.2.1 | An assignment will only be effective: |
(a) | on receipt by the Agent of written confirmation from the New Lender (in
form and substance satisfactory to the Agent) that the New Lender will assume the
same obligations to the Borrower and the other Finance Parties as it would have been
under if it was an Original Lender; |
(b) | on the New Lender entering into any documentation required for it to accede
as a party to any Security Document to which the Original Lender is a party in its
capacity as a Lender and, in relation to such Security Documents, completing any
filing, registration or notice requirements; and |
(c) | on the performance by the Agent of all “know your customer” or other checks
relating to any person that it is required to carry out in relation to such
assignment to a New Lender, the completion of which the Agent shall promptly notify
to the Lender and the New Lender. |
28.2.2 | Each New Lender, by executing the relevant Transfer Certificate, confirms, for the
avoidance of doubt, that the Agent has authority to execute on its behalf any amendment or
waiver that has been approved by or on behalf of the requisite Lender or Lenders in
accordance with the Finance Documents on or prior to the date on which the assignment becomes
effective in accordance with the Finance Documents and that it is bound by that decision to
the same extent as the Existing Lender would have been had it remained a Lender. |
|
28.3 | Fee |
|
The New Lender shall, on the date upon which an assignment takes effect, pay to the Agent
(for its own account) a fee of $6,000. |
84
28.4 | Limitation of responsibility of Existing Lenders |
|
28.4.1 | Unless expressly agreed to the contrary, an Existing Lender makes no representation or
warranty and assumes no responsibility to a New Lender for: |
(a) | the legality, validity, effectiveness, adequacy or enforceability of the
Finance Documents or any other documents; |
||
(b) | the financial condition of any Obligor; |
(c) | the performance and observance by any Obligor or any other person of its
obligations under the Finance Documents or any other documents; |
(d) | the application of any Basel 2 Regulation to the transactions contemplated
by the Finance Documents; or |
(e) | the accuracy of any statements (whether written or oral) made in or in
connection with any Finance Document or any other document, |
28.4.2 | Each New Lender confirms to the Existing Lender and the other Finance Parties and the
Finance Parties that it: |
(a) | has made (and shall continue to make) its own independent investigation and
assessment of: |
(i) | the financial condition and affairs of the Obligors and their
related entities in connection with its participation in this Agreement; and |
(ii) | the application of any Basel 2 Regulation to the transactions
contemplated by the Finance Document, |
(b) | will continue to make its own independent appraisal of the application of
any Basel 2 Regulation to the transactions contemplated by the Finance Documents; and |
(c) | will continue to make its own independent appraisal of the creditworthiness
of each Obligor and its related entities whilst any amount is or may be outstanding
under the Finance Documents or any Commitment is in force. |
85
28.4.3 | Nothing in any Finance Document obliges an Existing Lender to: |
(a) | accept a re-assignment from a New Lender of any of the rights assigned
under this clause 28 (Changes to the Lenders); or |
(b) | support any losses directly or indirectly incurred by the New Lender by
reason of the non-performance by any Obligor of its obligations under the Finance
Documents or by reason of the application of any Basel 2 Regulation to the
transactions contemplated by the Finance Documents or otherwise. |
28.5 | Procedure for transfer |
|
28.5.1 | Subject to the conditions set out in clause 28.2 (Conditions of assignment) an assignment
may be effected in accordance with clause 28.5.3 below when (a) the Agent executes an
otherwise duly completed Transfer Certificate and (b) the Agent executes any document
required under clause 28.2.1 which it may be necessary for it to execute in each case
delivered to it by the Existing Lender and the New Lender duly executed by them and, in the
case of any such other document, any other relevant person. The Agent shall, as soon as
reasonably practicable after receipt by it of a Transfer Certificate and any such other
document each duly completed, appearing on its face to comply with the terms of this
Agreement and delivered in accordance with the terms of this Agreement, execute that Transfer
Certificate and such other document. |
28.5.2 | The Obligors and the other Finance Parties irrevocably authorise the Agent to execute any
Transfer Certificate on their behalf without any consultations with them. |
28.5.3 | On the Transfer Date: |
(a) | to the extent that in the Transfer Certificate the Existing Lender seeks to
be released from its obligations under the Finance Documents, the Existing Lender
shall be released from further obligations towards the Obligors and the other Finance
Parties under the Finance Documents and the rights of the Obligors and the other
Finance Parties against the Existing Lender under the Finance Documents shall be
cancelled (being the Discharged Obligations) (but the obligations owed by the
Obligors under the Finance Documents shall not be released); |
(b) | the New Lender shall assume obligations towards each of the Obligors who
are a Party and/or the Obligors and the other Finance Parties shall acquire rights
against the New Lender which differ from the Discharged Rights and Obligations only
insofar as the New Lender has assumed and/or the Obligors and the other Finance
Parties have acquired the same in place of the Existing Lender; |
86
(c) | the other Finance Parties and the New Lender shall acquire the same rights
and assume the same obligations between themselves as they would have acquired and
assumed had the New Lender been an Original Lender with the rights and/or obligations
acquired or assumed by it as a result of the transfer and to that extent the Existing
Lender and the other Finance Parties shall each be released from further obligations
to each other under the Finance Documents; and |
(d) | the New Lender shall become a Party to the Finance Documents as a “Lender”
for the purposes of all the Finance Documents. |
28.6 | Copy of Transfer Certificate to Borrower |
|
The Agent shall, as soon as reasonably practicable after it has executed a Transfer
Certificate and any other document required under clause 28.2.1 (Conditions of assignment),
send a copy of that Transfer Certificate and such documents to the Borrower. |
||
29 | Changes to the Obligors |
|
No Obligor may assign any of its rights or transfer any of its rights or obligations under
the Finance Documents. |
87
30 | Roles of Agent, Security Agent and the Arranger |
|
30.1 | Appointment of the Agent |
|
30.1.1 | Each other Finance Party (other than the Security Agent) appoints the Agent to act as its
agent under and in connection with the Finance Documents. |
|
30.1.2 | Each such other Finance Party authorises the Agent: |
(a) | to exercise the rights, powers, authorities and discretions specifically
given to the Agent under or in connection with the Finance Documents together with
any other incidental rights, powers, authorities and discretions; and |
||
(b) | to execute each of the Security Documents and all other documents that may
be approved by the Majority Lenders for execution by it. |
30.2 | Duties of the Agent |
|
30.2.1 | The Agent shall promptly forward to a Party the original or a copy of any document which is
delivered to the Agent for that Party by any other Party. |
|
30.2.2 | Without prejudice to clause 28.6 (Copy of Transfer Certificate to Borrower), clause 30.2.1
shall not apply to any Transfer Certificate. |
|
30.2.3 | Except where a Finance Document specifically provides otherwise, the Agent is not obliged
to review or check the adequacy, accuracy or completeness of any document it forwards to
another Party. |
|
30.2.4 | If the Agent receives notice from a Party referring to this Agreement, describing a Default
and stating that the circumstance described is a Default, it shall promptly notify the other
Finance Parties. |
|
30.2.5 | If the Agent is aware of the non-payment of any principal, interest, commitment fee or
other fee payable to a Finance Party (other than the Agent or the Arranger or the Security
Agent for their own account) under this Agreement it shall promptly notify the other Finance
Parties. |
|
30.2.6 | Except as specifically provided in the Finance Documents, the Agent has no obligations of
any kind to any other Party under or in connection with the Finance Documents. The Agent’s
duties under the Finance Documents are solely mechanical and administrative in nature. |
88
30.3 | Role of the Arranger |
|
Except as specifically provided in the Finance Documents, the Arranger has no obligations of
any kind to any other Party under or in connection with any Finance Document or the
transactions contemplated by the Finance Documents. |
||
30.4 | No fiduciary duties |
|
30.4.1 | Nothing in this Agreement constitutes the Agent or the Arranger as a trustee or fiduciary
of any other person. |
|
30.4.2 | None of the Agent, the Security Agent or the Arranger shall be bound to account to any
Lender for any sum or the profit element of any sum received by it for its own account or
have any obligations to the other Finance Parties beyond those expressly stated in the
Finance Documents. |
|
30.5 | Business with the Group |
|
The Agent, the Security Agent and the Arranger may accept deposits from, lend money to and
generally engage in any kind of banking or other business with any Obligor or other Group
Member or their Affiliates. |
||
30.6 | Rights and discretions of the Agent |
|
30.6.1 | The Agent may rely on: |
(a) | any representation, notice or document believed by it to be genuine,
correct and appropriately authorised; and |
||
(b) | any statement made by a director, authorised signatory or employee of any
person regarding any matters which may reasonably be assumed to be within his or her
knowledge or within his or her power to verify. |
30.6.2 | The Agent may assume (unless it has received notice to the contrary in its capacity as
agent for the other Finance Parties) that: |
(a) | no Default has occurred (unless it has actual knowledge of a Default
arising under clause 27.1 (Non-payment)); |
||
(b) | any right, power, authority or discretion vested in any Party or the
Majority Lenders has not been exercised; and |
||
(c) | any notice or request made by the Borrower (other than a Utilisation
Request is made on behalf of and with the consent and knowledge of all the Obligors. |
89
30.6.3 | The Agent may engage, pay for and rely on the advice or services of any lawyers,
accountants, surveyors or other experts in the conduct of its obligations and
responsibilities under the Finance Documents. |
|
30.6.4 | The Agent may act in relation to the Finance Documents through its personnel and agents. |
|
30.6.5 | The Agent may disclose to any other Party any information it reasonably believes it has
received as agent under this Agreement. |
|
30.6.6 | Notwithstanding any other provision of any Finance Document to the contrary, neither the
Agent nor the Arranger is obliged to do or omit to do anything if it would or might in its
reasonable opinion constitute a breach of any law or regulation or a breach of a fiduciary
duty or duty of confidentiality. The Agent and the Arranger may do anything which in its
opinion, is necessary or desirable to comply with any law or regulation of any jurisdiction. |
|
30.7 | Majority Lenders’ instructions |
|
30.7.1 | Unless a contrary indication appears in a Finance Document, the Agent shall: |
(a) | exercise any right, power, authority or discretion vested in it as Agent
(including giving instructions to the Security Agent) in accordance with any
instructions given to it by the Majority Lenders (or, if so instructed by the
Majority Lenders, refrain from exercising any right, power, authority or discretion
vested in it as Agent); and |
||
(b) | not be liable for any act (or omission) if it acts (or refrains from taking
any action) in accordance with an instruction of the Majority Lenders. |
30.7.2 | Unless a contrary indication appears in a Finance Document, any instructions given by the
Majority Lenders to the Agent (in relation to any right, power, authority or discretion
vested in it as Agent) shall be binding on all the Finance Parties (other than the Security
Agent). |
|
30.7.3 | The Agent may refrain from acting in accordance with the instructions of the Majority
Lenders (or, if appropriate, the Lenders) until it has received such security as it may
require for any cost, loss or liability (together with any associated VAT) which it may incur
in complying with the instructions. |
|
30.7.4 | In the absence of, or while awaiting, instructions from the Majority Lenders (or, if
appropriate, the Lenders), the Agent may act (or refrain from taking action) as it considers
to be in the best interest of the Finance Parties. |
|
30.7.5 | The Agent is not authorised to act on behalf of a Lender (without first obtaining that
Lender’s consent) in any legal or arbitration proceedings relating to any Finance Document.
This clause 30.7.5 shall not apply to any legal or arbitration proceeding relating to the
perfection, preservation or protection of rights under the Security Documents or enforcement
of the Security Documents. |
90
30.7.6 | Neither the Agent nor the Arranger shall be obliged to request any certificate, opinion or
other information under clause 19 (Information undertakings) unless so required in writing by
a Lender, in which case the Agent shall promptly make the appropriate request of the Borrower
if such request would be in accordance with the terms of this Agreement. |
|
30.8 | Responsibility for documentation and other matters |
|
Neither the Agent nor the Arranger: |
(a) | is responsible for the adequacy, accuracy and/or completeness of any
information (whether oral or written) supplied by the Agent, the Arranger, an Obligor
or any other person given in or in connection with any Finance Document or the
transactions contemplated in the Finance Documents or of any representations in any
Finance Document or of any copy of any document delivered under any Finance Document; |
||
(b) | is responsible for the legality, validity, effectiveness, adequacy or
enforceability of any Finance Document or the Building Contract or any other
agreement, arrangement or document entered into, made or executed in anticipation of
or in connection with any Finance Document or the Building Contract; |
||
(c) | is responsible for the application of any Basel 2 Regulation to the
transactions contemplated by the Finance Documents; |
||
(d) | is responsible for any loss to the Trust Property arising in consequence of
the failure, depreciation or loss of any Charged Property or any investments made or
retained in good faith or by reason of any other matter or thing; |
||
(e) | is obliged to account to any person for any sum or the profit element of
any sum received by it for its own account; |
||
(f) | is responsible for the failure of any Obligor or any other party to perform
its obligations under any Finance Document or the Building Contract or the financial
condition of any such person; |
||
(g) | is responsible to ascertain whether all deeds and documents which should
have been deposited with it (or the Security Agent and/or any other beneficiary of a
Security Document) under or pursuant to any of the Security Documents have been so
deposited; |
||
(h) | is responsible to investigate or make any enquiry into the title of any
Obligor to any of the Charged Property or any of its other property or assets; |
91
(i) | is responsible for the failure to register any of the Security Documents
with the Registrar of Companies or any other public office or for the perfection of
any Security Documents; |
||
(j) | is responsible for the failure to register any of the Security Documents in
accordance with the provisions of the documents of title of any Obligor to any of the
Charged Property; |
||
(k) | is responsible for the failure to take or require any Obligor to take any
steps to render any of the Security Documents effective as regards property or assets
outside England or Wales or to secure the creation of any ancillary charge under the
laws of the jurisdiction concerned; or |
||
(l) | is (unless it is the same entity as the Security Agent) responsible on
account of the failure of the Security Agent and/or any other beneficiary of a
Security Document to perform or discharge any of its duties or obligations under the
Security Documents; or |
||
(m) | for any determination as to whether any information provided or to be
provided to any Finance Party is non-public information the use of which may be
regulated or prohibited by any applicable law relating to insider dealing or
otherwise. |
30.9 | Exclusion of liability |
|
30.9.1 | Without limiting clause 30.9.2, the Agent will not be liable for any action taken by it
under or in connection with any Finance Document, unless directly caused by its gross
negligence or wilful misconduct. |
|
30.9.2 | No Party (other than the Agent) may take any proceedings against any officer, employee or
agent of the Agent in respect of any claim it might have against the Agent or in respect of
any act or omission of any kind by that officer, employee or agent in relation to any Finance
Document any officer, employee or agent of the Agent may rely on this clause subject to
clause 1.3 (Third party rights) and the provisions of the Third Parties Act. |
|
30.9.3 | The Agent will not be liable for any delay (or any related consequences) in crediting an
account with an amount required under the Finance Documents to be paid by the Agent if the
Agent has taken all necessary steps as soon as reasonably practicable to comply with the
regulations or operating procedures of any recognised clearing or settlement system used by
the Agent for that purpose. |
|
30.9.4 | Nothing in this Agreement shall oblige the Agent nor the Arranger to carry out any “know
your customer” or other checks in relation to any person on behalf of any Lender and each
Lender confirms to the Agent and the Arranger that it is solely responsible for any such
checks it is required to carry out and that it may not rely on any statement in relation to
such checks made by the Agent or the Arranger. |
92
30.10 | Lenders’ indemnity to the Agent |
|
Each Lender shall (in proportion to its share of the Total Commitments or, if the Total
Commitments are then zero, to its share of the Total Commitments immediately prior to their
reduction to zero) indemnify the Agent, within three Business Days of demand, against any
Losses (otherwise than by reason of the Agent’s gross negligence or wilful misconduct)
including the costs of any person engaged in accordance with clause 30.6.3 (Rights and
discretions of the Agent) and any Receiver in acting as its agent under the Finance Documents
incurred by the Agent in acting as such under the Finance Documents (unless the Agent has
been reimbursed by an Obligor pursuant to a Finance Document or out of the Trust Property). |
||
30.11 | Resignation of the Agent |
|
30.11.1 | The Agent may resign and appoint one of its Affiliates as successor by giving notice to
the Lenders, the Security Agent and the Borrower. |
|
30.11.2 | Alternatively the Agent may resign by giving notice to the other Finance Parties and the
Borrower, in which case the Majority Lenders (after consultation with the Borrower) may
appoint a successor Agent. |
|
30.11.3 | If the Majority Lenders have not appointed a successor Agent in accordance with clause
30.11.2 above within 30 days after notice of resignation was given, the Agent (after
consultation with the Borrower) may appoint a successor Agent. |
|
30.11.4 | The retiring Agent shall, either at the Lenders’ expense if it has been required to resign
pursuant to clause 30.11.7 or otherwise at its own cost, make available to the successor
Agent such documents and records and provide such assistance as the successor Agent may
reasonably request for the purposes of performing its functions as Agent under the Finance
Documents. |
|
30.11.5 | The Agent’s resignation notice shall only take effect upon the appointment of a successor. |
|
30.11.6 | Upon the appointment of a successor, the retiring Agent shall be discharged from any
further obligation in respect of the Finance Documents but shall remain entitled to the
benefit of this clause 30. Its successor and each of the other Parties shall have the same
rights and obligations amongst themselves as they would have had if such successor had been
an original Party. |
|
30.11.7 | The Majority Lenders may, by notice to the Agent, require it to resign in accordance with
clause 30.11.2. In this event, the Agent shall resign in accordance with clause 30.11.2. |
|
30.11.8 | Notwithstanding any other provision of this Agreement, no successor may be appointed as
Agent unless that same successor is simultaneously appointed as “Agent” under the
corresponding provisions of clause 30.11.8 of the Beta Facility Agreement. |
93
30.12 | Confidentiality |
|
30.12.1 | In acting as agent for the Finance Parties, the Agent shall be regarded as acting through
its department, division or team directly responsible for the management of the Finance
Documents which shall be treated as a separate entity from any other of its divisions,
departments or teams. |
|
30.12.2 | If information is received by another division or department of the Agent, it may be
treated as confidential to that division or department and the Agent shall not be deemed to
have notice of it. |
|
30.12.3 | Notwithstanding any other provision of any Finance Document to the contrary, neither the
Agent, nor the Arranger is obliged to disclose to any other person (a) any confidential
information or (b) any other information if the disclosure would or might in its reasonable
opinion constitute a breach of any law or a breach of a fiduciary duty. |
|
30.13 | Relationship with the Lenders |
|
30.13.1 | The Agent may treat the person shown in its records as Lender at the opening of business
(in the place of its principal office as notified to the Finance Parties from time to time)
as the Lender acting through its Facility Office: |
(a) | entitled to or liable for any payment due under any Finance Document on
that day; and |
||
(b) | entitled to receive and act upon any notice, request, document or
communication or make any decision or determination under any Finance Document made
or delivered on that day, |
unless it has received not less than five Business Days prior notice from that Lender to the
contrary in accordance with the terms of this Agreement. |
||
30.13.2 | Each Lender shall supply the Agent with any information that the Agent may reasonably
specify as being necessary or desirable to enable the Agent or the Security Agent to perform
its functions as Agent or Security Agent. Each Lender shall deal with the Security Agent
exclusively through the Agent and shall not deal directly with the Security Agent. |
|
30.14 | Credit appraisal by the Lenders |
|
Without affecting the responsibility of any Obligor for information supplied by it or on its
behalf in connection with any Finance Document, each Lender confirms to each other Finance
Party that it has been, and will continue to be, solely responsible for making its own
independent appraisal and investigation of all risks arising under or in connection with any
Finance Document including but not limited to: |
(a) | the financial condition, status and nature of each Obligor and other Group
Member; |
94
(b) | the legality, validity, effectiveness, adequacy or enforceability of any Finance
Document or the Building Contract and any other agreement, arrangement or document
entered into, made or executed in anticipation of, under or in connection with any
Finance Document or the Building Contract; |
||
(c) | the application of any Basel 2 Regulation to the transactions contemplated
by the Finance Documents; |
||
(d) | whether any Finance Party has recourse, and the nature and extent of that
recourse, against any Party or any of its respective assets under or in connection
with any Finance Document, the transactions contemplated by the Finance Documents or
any other agreement, arrangement or document entered into, made or executed in
anticipation of, under or in connection with any Finance Document; |
||
(e) | the adequacy, accuracy and/or completeness of any information provided by
the Agent, any Party or by any other person under or in connection with any Finance
Document or the Building Contract, the transactions contemplated by the Finance
Documents or any other agreement, arrangement or document entered into, made or
executed in anticipation of, under or in connection with any Finance Document or the
Building Contract; and |
||
(f) | the right of title of any person to, or the value or sufficiency of, any
part of the Charged Property, the priority of the Security Documents or the existence
of any Security Interest affecting the Charged Property. |
30.15 | Agent’s management time |
|
Any amount payable to the Agent under clause 14.3 (Indemnity to the Agent), clause 16 (Costs
and expenses) and clause 30.10 (Lenders’ indemnity to the Agent) shall include the cost of
utilising the Agent’s management time or other resources and will be calculated on the basis
of such reasonable daily or hourly rates as the Agent may notify to the Borrower and the
Lenders, and is in addition to any fee paid or payable to the Agent under clause 11 (Fees). |
||
30.16 | Deduction from amounts payable by the Agent |
|
If any Party owes an amount to the Agent under the Finance Documents the Agent may, after
giving notice to that Party, deduct an amount not exceeding that amount from any payment to
that Party which the Agent would otherwise be obliged to make under the Finance Documents and
apply the amount deducted in or towards satisfaction of the amount owed. For the purposes of
the Finance Documents that Party shall be regarded as having received any amount so deducted. |
95
30.17 | Common parties |
|
Although the Agent and the Security Agent may from time to time be the same entity, that
entity will have entered into the Finance Documents (to which it is party) in its separate
capacities as agent for the Finance Parties and (as appropriate) security agent and trustee
for the Finance Parties. Where any Finance Document provides for the Agent or Security Agent
to communicate with or provide instructions to the other, while they are the same entity,
such communication or instructions will not be necessary. |
||
30.18 | Security Agent |
|
30.18.1 | Each other Finance Party appoints the Security Agent to act as its agent and (to the
extent permitted under any applicable law) trustee under and in connection with the Security
Documents and confirms that the Security Agent shall have a lien on the Security Documents
and the proceeds of the enforcement of those Security Documents for all moneys payable to the
beneficiaries of those Security Documents. |
|
30.18.2 | Each other Finance Party authorises the Security Agent: |
(a) | to exercise the rights, powers, authorities and discretions specifically
given to the Security Agent under or in connection with the Finance Documents
together with any other incidental rights, powers, authorities and discretions; and |
||
(b) | to execute each of the Security Documents and all other documents that may
be approved by the Agent and/or the Majority Lenders for execution by it. |
30.18.3 | The Security Agent accepts its appointment under clause 30.18 as trustee of the Trust
Property with effect from the date of this Agreement and declares that it holds the Trust
Property on trust for itself, the other Finance Parties (for so long as they are Finance
Parties) on and subject to the terms set out in clauses 30.18 — 30.26 (inclusive) and the
Security Documents to which it is a party. |
|
30.19 | Application of certain clauses to Security Agent |
|
30.19.1 | Clauses 30.6 (Rights and discretions of the Agent), 30.8 (Responsibility for documentation
and other matters), 30.9 (Exclusion of liability), 30.10 (Lenders’ indemnity to the Agent),
30.11 (Resignation of the Agent), 30.12 (Confidentiality), 30.13 (Relationship with the
Lenders), 30.14 (Credit appraisal by the Lenders) and 30.16 (Deduction from amounts payable
by the Agent) shall each extend so as to apply to the Security Agent in its capacity as such
and for that purpose each reference to the “Agent” in these clauses shall extend to include
in addition a reference to the “Security Agent” in its capacity as such. |
96
30.19.2 | In addition, clause 30.11 (Resignation of the Agent) shall, for the purposes of its
application to the Security Agent pursuant to clause 30.19.1, have the following additional
sub-clause: |
At any time after the appointment of a successor, the retiring Security Agent shall
do and execute all acts, deeds and documents reasonably required by its successor to
transfer to it (or its nominee, as it may direct) any property, assets and rights
previously vested in the retiring Security Agent pursuant to the Security Documents
and which shall not have vested in its successor by operation of law. All such acts,
deeds and documents shall be done or, as the case may be, executed at the cost of the
retiring Security Agent (except where the Security Agent is retiring under clause
30.11.7 (Resignation of the Agent) as extended to it by clause 30.19.1, in which case
such costs shall be borne by the Lenders (in proportion to its share of the Total
Commitments or, if the Total Commitments are then zero, to its share of the Total
Commitments immediately prior to their reduction to zero)). |
30.20 | Instructions to Security Agent |
|
30.20.1 | Unless a contrary indication appears in a Finance Document, the Security Agent shall: |
(a) | exercise any right, power, authority or discretion vested in it as Security
Agent in accordance with any instructions given to it by the Agent (or, if so
instructed by the Agent, refrain from exercising any right, power, authority or
discretion vested in it as Security Agent); and |
||
(b) | not be liable for any act (or omission) if it acts (or refrains from taking
any action) in accordance with such an instruction of the Agent (the Agent in each
case acting on the instructions of the Majority Lenders or, if appropriate pursuant
to clause 39.2 (Exceptions), the Lenders). |
30.20.2 | Unless a contrary indication appears in a Finance Document, any instructions given by the
Agent to the Security Agent in accordance with clause 30.20.1 will be binding on the Finance
Parties. |
|
30.20.3 | The Security Agent may refrain from acting in accordance with the instructions of the
Agent until it has received such security as it may require for any cost, loss or liability
(together with any associated VAT) which it may incur in complying with the instructions. |
|
30.20.4 | In the absence of, or while awaiting, instructions from the Agent, (including in
exceptional circumstances where time does not permit the Agent obtaining instructions from
the Lenders and urgent action is required) the Security Agent may act (or refrain from taking action) as
it considers to be in the best interest of the Finance Parties. |
97
30.20.5 | The Security Agent is not authorised to act on behalf of another Finance Party (without
first obtaining that Finance Party’s consent) in any legal or arbitration proceedings
relating to any Finance Document but this is without prejudice to clauses 30.20.1 and
30.20.4, including the right to enforce the Security Documents in accordance with these
clauses. |
|
30.21 | Order of application upon enforcement |
|
30.21.1 | The Security Agent agrees to apply the Trust Property and each other beneficiary of the
Security Documents agrees to apply all moneys received by it in the exercise of its rights
under the Security Documents in accordance with the following respective claims: |
(a) | first, as to a sum equivalent to the amounts payable to the Security Agent
under the Finance Documents (excluding any amounts received by the Security Agent
pursuant to clause 30.10 (Lenders’ indemnity to the Agent) as extended to the
Security Agent pursuant to clause 30.19 (Application of certain clauses to Security
Agent)), for the Security Agent absolutely; |
||
(b) | secondly, as to a sum equivalent to the aggregate amount then due and owing
to the other Finance Parties under this Agreement or under any other Finance
Documents which may be attributable to the Facility, for those Finance Parties
absolutely, and pro-rata to the amounts owing to them under this Agreement or under
any other Finance Documents which may be attributable to the Facility; |
||
(c) | thirdly, as to a sum equivalent to the aggregate amount then due and owing
to the Beta Finance Parties under the Beta Facility Agreement or under any other
Finance Documents which may be attributable to the Beta Facility Agreement for those
Beta Finance Parties absolutely, and pro-rata to the amounts owing to them under the
Beta Facility Agreement or under any other Finance Documents which may be
attributable to the Beta Facility Agreement; |
||
(d) | fourthly, until such time as the Security Agent is satisfied that all
obligations owed to the Finance Parties have been irrevocably and unconditionally
discharged in full, held by the Security Agent on a suspense account for payment of
any further amounts owing to the Finance Parties under the Finance Documents and
further application in accordance with this clause 30.21.1 as and when any such
amounts later fall due; |
||
(e) | fifthly, to the Builder pursuant to the Building Contract Addendum with
respect to Deferred Instalment I or, as the case may be, pursuant to the Beta
Building Contract Addendum with respect to Beta Deferred Instalment I or to such
other persons (if any) as are legally entitled thereto in priority to the Obligors; |
||
(f) | sixthly, to the Builder pursuant to the Building Contract Addendum with respect to
Deferred Instalment II or, as the case may be, pursuant to the Beta Building Contract
Addendum with respect to Beta Deferred Instalment II or to such other persons (if
any) as are legally entitled thereto in priority to the Obligors; |
98
(g) | seventhly, as to the balance (if any), for the Obligors by or from whom or
from whose assets the relevant amounts were paid, received or recovered or other
person entitled to them. |
30.21.2 | The Security Agent and each other beneficiary of the Security Documents shall make each
application as soon as is practicable after the relevant moneys are received by, or otherwise
become available to, it save that (without prejudice to any other provision contained in any
of the Security Documents) the Security Agent (acting on the instructions of the Agent), any
other beneficiary of the Security Documents or any receiver or administrator may credit any
moneys received by it to a suspense account for so long and in such manner as the Security
Agent, such other beneficiary of the Security Documents or such receiver or administrator may
from time to time determine with a view to preserving the rights of the Finance Parties or
any of them to prove for the whole of their respective claims against the Borrower or any
other person liable. |
|
30.21.3 | The Security Agent and/or any other beneficiary of the Security Documents shall obtain a
good discharge in respect of the amounts expressed to be due to the other Finance Parties as
referred to in this clause 30.21 by paying such amounts to the Agent for distribution in
accordance with clause 33 (Payment mechanics). |
|
30.22 | Perpetuities |
|
The perpetuity period to the extent applicable to this Agreement and the other Finance
Documents shall be 125 years from the date of this Agreement. |
||
30.23 | Powers and duties of the Security Agent as trustee of the security |
|
In its capacity as trustee in relation to the Trust Property, the Security Agent: |
(a) | shall, without prejudice to any of the powers, discretions and immunities
conferred upon trustees by law (and to the extent not inconsistent with the
provisions of this Agreement or any of the Security Documents), have all the same
powers and discretions as a natural person acting as the beneficial owner of such
property and/or as are conferred upon the Security Agent by this Agreement and/or any
Security Document but so that the Security Agent may only exercise such powers and
discretions to the extent that it is authorised to do so by the provisions of this
Agreement; |
99
(b) | shall (subject to clause 30.21 (Order of application)) be entitled (in its own name
or in the names of nominees) to invest moneys from time to time forming part of the
Trust Property or otherwise held by it as a consequence of any enforcement of the
security constituted by any Finance Document which, in the reasonable opinion of the
Security Agent, it would not be practicable to distribute immediately, by placing the
same on deposit in the name or under the control of the Security Agent as the
Security Agent may think fit without being under any duty to diversify the same and
the Security Agent shall not be responsible for any loss due to interest rate or
exchange rate fluctuations except for any loss arising from the Security Agent’s
gross negligence or wilful misconduct; |
||
(c) | may, in the conduct of its obligations under and in respect of the Security
Documents (otherwise than in relation to its right to make any declaration,
determination or decision), instead of acting personally, employ and pay any agent
(whether being a lawyer or any other person) to transact or concur in transacting any
business and to do or concur in doing any acts required to be done by the Security
Agent (including the receipt and payment of money) and on the basis that (i) any such
agent engaged in any profession or business shall be entitled to be paid all usual
professional and other charges for business transacted and acts done by him or any
partner or employee of his or her in connection with such employment and (ii) the
Security Agent shall not be bound to supervise, or be responsible for any loss
incurred by reason of any act or omission of, any such agent if the Security Agent
shall have exercised reasonable care in the selection of such agent; and |
||
(d) | may place all deeds and other documents relating to the Trust Property
which are from time to time deposited with it pursuant to the Security Documents in
any safe deposit, safe or receptacle selected by the Security Agent exercising
reasonable care or with any firm of solicitors or company whose business includes
undertaking the safe custody of documents selected by the Security Agent exercising
reasonable care and may make any such arrangements as it thinks fit for allowing
Obligors access to, or its solicitors or auditors possession of, such documents when
necessary or convenient and the Security Agent shall not be responsible for any loss
incurred in connection with any such deposit, access or possession if it has
exercised reasonable care in the selection of a safe deposit, safe, receptacle or
firm of solicitors or company (save that it shall take reasonable steps to pursue any
person who may be liable to it in connection with such loss). |
30.24 | All enforcement action through the Security Agent |
|
30.24.1 | None of the other Finance Parties shall have any independent power to enforce any of those
Security Documents which are executed in favour of the Security Agent only or to exercise any
rights, discretions or powers or to grant any consents or releases under or pursuant to such
Security Documents or otherwise have direct recourse to the security and/or guarantees
constituted by such Security Documents except through the Security Agent. |
100
30.24.2 | None of the other Finance Parties shall have any independent power to enforce any of those
Security Documents which are executed in their favour or to exercise any rights, discretions
or powers or to grant any consents or releases under or pursuant to such Security Documents
or otherwise have direct recourse to the security and/or guarantees constituted by such
Security Documents except through the Security Agent. If any Finance Party (other than the
Security Agent) is a party to any Security Document it shall promptly upon being requested by
the Agent to do so grant a power of attorney or other sufficient authority to the Security
Agent to enable the Security Agent to exercise any rights, discretions or powers or to grant
any consents or releases under such Security Document. |
|
30.25 | Co-operation to achieve agreed priorities of application |
|
The other Finance Parties shall co-operate with each other and with the Security Agent and
any receiver or administrator under the Security Documents in realising the property and
assets subject to the Security Documents and in ensuring that the net proceeds realised under
the Security Documents after deduction of the expenses of realisation are applied in
accordance with clause 30.21 (Order of application). |
||
30.26 | Indemnity from Trust Property |
|
30.26.1 | In respect of all liabilities, costs or expenses for which the Obligors are liable under
this Agreement, the Security Agent and each Affiliate of the Security Agent and each officer
or employee of the Security Agent or its Affiliate (each a Relevant Person) shall be entitled
to be indemnified out of the Trust Property in respect of all liabilities, damages, costs,
claims, charges or expenses whatsoever properly incurred or suffered by such Relevant Person: |
(a) | in the execution or exercise or bona fide purported execution or exercise
of the trusts, rights, powers, authorities, discretions and duties created or
conferred by or pursuant to the Finance Documents; |
||
(b) | as a result of any breach by an Obligor of any of its obligations under any
Finance Document; |
||
(c) | in respect of any Environmental Claim made or asserted against a Relevant
Person which would not have arisen if the Finance Documents had not been executed;
and |
||
(d) | in respect of any matter or thing done or omitted in any way in accordance
with the terms of the Finance Documents relating to the Trust Property or the
provisions of any of the Finance Documents. |
101
30.26.2 | The rights conferred by this clause 30.26 are without prejudice to any right to indemnity by
law given to trustees generally and to any provision of the Finance Documents entitling the
Security Agent or any other person to an indemnity in respect of, and/or reimbursement of,
any liabilities, costs or expenses incurred or suffered by it in connection with any of the
Finance Documents or the performance of any duties under any of the Finance Documents.
Nothing contained in this clause 30.26 shall entitle the Security Agent or any other person
to be indemnified in respect of any liabilities, damages, costs, claims, charges or expenses
to the extent that the same arise from such person’s own gross negligence or wilful
misconduct. |
|
30.27 | Finance Parties to provide information |
|
The other Finance Parties shall provide the Security Agent with such written information as
it may reasonably require for the purposes of carrying out its duties and obligations under
the Security Documents and, in particular, with such necessary directions in writing so as to
enable the Security Agent to make the calculations and applications contemplated by clause
30.21 (Order of application) above and to apply amounts received under, and the proceeds of
realisation of, the Security Documents as contemplated by the Security Documents, clause 33.5
(Partial payments) and clause 30.21 (Order of application). |
||
30.28 | Release to facilitate enforcement and realisation |
|
Each Finance Party acknowledges that pursuant to any enforcement action by the Security Agent
(or a Receiver) carried out on the instructions of the Agent it may be desirable for the
purpose of such enforcement and/or maximising the realisation of the Charged Property being
enforced against, that any rights or claims of or by the Security Agent (for the benefit of
the Finance Parties) and/or any Finance Parties against any Obligor and/or any Security
Interest over any assets of any Obligor (in each case) as contained in or created by any
Finance Document, other than such rights or claims or security being enforced, be released in
order to facilitate such enforcement action and/or realisation and, notwithstanding any other
provision of the Finance Documents, each Finance Party hereby irrevocably authorises the
Security Agent (acting on the instructions of the Agent) to grant any such releases to the
extent necessary to fully effect such enforcement action and realisation including, without
limitation, to the extent necessary for such purposes to execute release documents in the
name of and on behalf of the Finance Parties. Where the relevant enforcement is by way of
disposal of shares in the Borrower, the requisite release shall include releases of all
claims (including under guarantees) of the Finance Parties and/or the Security Agent against
the Borrower and of all Security Interests over the assets of the Borrower. |
||
30.29 | Undertaking to pay |
|
Each Obligor which is a Party undertakes with the Security Agent on behalf of the Finance
Parties that it will, on demand by the Security Agent, pay to the Security Agent all money
from time to time owing, and discharge all other obligations from time to time incurred, by
it under or in connection with the Finance Documents. |
102
30.30 | Additional trustees |
|
The Security Agent shall have power by notice in writing to the other Finance Parties and the
Borrower to appoint any person approved by the Borrower (such approval not to be unreasonably
withheld or delayed) either to act as separate trustee or as co-trustee jointly with the
Security Agent: |
(a) | if the Security Agent reasonably considers such appointment to be in the
best interests of the Finance Parties; |
||
(b) | for the purpose of conforming with any legal requirement, restriction or
condition in any jurisdiction in which any particular act is to be performed; or |
||
(c) | for the purpose of obtaining a judgment in any jurisdiction or the
enforcement in any jurisdiction against any person of a judgment already obtained, |
and any person so appointed shall (subject to the provisions of this Agreement) have such
rights (including as to reasonable remuneration), powers, duties and obligations as shall be
conferred or imposed by the instrument of appointment. The Security Agent shall have power
to remove any person so appointed. At the request of the Security Agent, the other parties
to this Agreement shall forthwith execute all such documents and do all such things as may be
required to perfect such appointment or removal and each such party irrevocably authorises
the Security Agent in its name and on its behalf to do the same. Such a person shall accede
to this Agreement as a Security Agent to the extent necessary to carry out their role on
terms satisfactory to the Security Agent and (subject always to the provisions of this
Agreement) have such trusts, powers, authorities, liabilities and discretions (not exceeding
those conferred on the Security Agent by this Agreement and the other Finance Documents) and
such duties and obligations as shall be conferred or imposed by the instrument of appointment
(being no less onerous than would have applied to the Security Agent but for the
appointment). The Security Agent shall not be bound to supervise, or be responsible for any
loss incurred by reason of any act or omission of, any such person if the Security Agent
shall have exercised reasonable care in the selection of such person. |
||
30.31 | Non-recognition of trust |
|
It is agreed by all the parties to this Agreement that: |
(a) | in relation to any jurisdiction the courts of which would not recognise or
give effect to the trusts expressed to be constituted by this clause 30, the
relationship of the Security Agent and the other Finance Parties shall be construed
as one of principal and agent, but to the extent permissible under the laws of such
jurisdiction, all the other provisions of this Agreement shall have full force and
effect between the parties to this Agreement; and |
103
(b) | the provisions of this clause 30 insofar as they relate to the Security
Agent in its capacity as trustee for the Finance Parties and the relationship between
themselves and the Security Agent as their trustee may be amended by agreement
between the other Finance Parties and the Security Agent. The Security Agent may
amend all documents necessary to effect the alteration of the relationship between
the Security Agent and the other Finance Parties and each such other party
irrevocably authorises the Security Agent in its name and on its behalf to execute
all documents necessary to effect such amendments. |
31 | Conduct of business by the Finance Parties |
|
31.1 | Finance Parties tax affairs |
|
No provision of this Agreement will: |
(a) | interfere with the right of any Finance Party to arrange its affairs (tax
or otherwise) in whatever manner it thinks fit; |
||
(b) | oblige any Finance Party to investigate or claim any credit, relief,
remission or repayment available to it or the extent, order and manner of any claim;
or |
||
(c) | oblige any Finance Party to disclose any information relating to its
affairs (tax or otherwise) or any computations in respect of Tax. |
31.2 | Finance Parties acting together |
|
Notwithstanding clause 2.2 (Finance Parties’ rights and obligations), if the Agent makes a
declaration under clause 27.21 (Acceleration) the Agent shall, in the names of all the
Finance Parties, take such action on behalf of the Finance Parties and conduct such
negotiations with the Borrower and any Group Members and generally administer the Facility in
accordance with the wishes of the Majority Lenders. All the Finance Parties shall be bound
by the provisions of this clause and no Finance Party shall be entitled to take action
independently against any Obligor or any of its assets without the prior consent of the
Majority Lenders. |
||
This clause shall not override clause 30 (Roles of Agent, Security Agent and the Arranger) as
it applies to the Security Agent. |
||
31.3 | Majority Lenders |
|
31.3.1 | Where any Finance Document provides for any matter to be determined by reference to the
opinion of, or to be subject to the consent, approval or request of, the Majority Lenders or
for any action to be taken on the instructions of the Majority Lenders (a majority decision),
such majority decision shall (as between the Lenders) only be regarded as having been validly
given or issued by the Majority Lenders if all the Lenders shall have received prior notice
of the matter on which such majority decision is required and the relevant majority of
Lenders shall have given or issued such majority decision. However (as between any Obligor
and the Finance Parties) the relevant Obligor shall be entitled (and bound) to assume that
such notice shall have been duly received by each Lender and that the relevant majority shall
have been obtained to constitute Majority Lenders when notified to this effect by the Agent
whether or not this is the case. |
104
31.3.2 | If, within ten Business Days of the Agent despatching to each Lender a notice requesting
instructions (or confirmation of instructions) from the Lenders or the agreement of the
Lenders to any amendment, modification, waiver, variation or excuse of performance for the
purposes of, or in relation to, any of the Finance Documents (or within such other period as
the Agent may specify in such notice), the Agent has not received a reply specifically giving
or confirming or refusing to give or confirm the relevant instructions or, as the case may
be, approving or refusing to approve the proposed amendment, modification, waiver, variation
or excuse of performance, then (irrespective of whether such Lender responds at a later date)
the Agent shall treat any Lender which has not so responded as having indicated a desire to
be bound by the wishes of 662/3 per cent. of those Lenders (measured in
terms of the total Commitments of those Lenders) which have so responded. |
|
31.3.3 | For the purposes of clause 31.3.2, any Lender which notifies the Agent of a wish or
intention to abstain on any particular issue shall be treated as if it had not responded. |
|
31.3.4 | Clauses 31.3.2 and 31.3.3 shall not apply in relation to those matters referred to in, or
the subject of, clause 39.2 (Exceptions). |
|
31.4 | Conflicts |
|
31.4.1 | The Borrower acknowledges that the Arranger and its parent undertaking, subsidiary
undertakings and fellow subsidiary undertakings (together the Arranger Group) may be
providing debt finance, equity capital or other services (including financial advisory
services) to other persons with which the Borrower may have conflicting interests in respect
of the Facility or otherwise. |
|
31.4.2 | No member of the Arranger Group shall use confidential information gained from any Obligor
by virtue of the Facility or its relationships with any Obligor in connection with their
performance of services for other persons. This shall not, however, affect any obligations
that any member of the Arranger Group has as Agent in respect of the Finance Documents. The
Borrower also acknowledges that no member of the Arranger Group has any obligation to use or
furnish to any Obligor information obtained from other persons for their benefit. |
|
31.4.3 | The terms parent undertaking, subsidiary undertaking and fellow subsidiary undertaking when
used in this clause have the meaning given to them in sections 1161 and 1162 of the Companies
Xxx 0000. |
105
32 | Sharing among the Finance Parties |
|
32.1 | Payments to Finance Parties |
|
If a Finance Party (a Recovering Finance Party) receives or recovers any amount from an
Obligor other than in accordance with clause 33 (Payment mechanics) (a Recovered Amount) and
applies that amount to a payment due under the Finance Documents then: |
(a) | the Recovering Finance Party shall, within three Business Days, notify
details of the receipt or recovery, to the Agent; |
||
(b) | the Agent shall determine whether the receipt or recovery is in excess of
the amount the Recovering Finance Party would have been paid had the receipt or
recovery been received or made by the Agent and distributed in accordance with clause
33 (Payment mechanics), without taking account of any Tax which would be imposed on
the Agent in relation to the receipt, recovery or distribution; and |
||
(c) | the Recovering Finance Party shall, within three Business Days of demand by
the Agent, pay to the Agent an amount (the Sharing Payment) equal to such receipt or
recovery less any amount which the Agent determines may be retained by the Recovering
Finance Party as its share of any payment to be made, in accordance with clause 33.5
(Partial payments). |
32.2 | Redistribution of payments |
|
The Agent shall treat the Sharing Payment as if it had been paid by the relevant Obligor and
distribute it between the Finance Parties (other than the Recovering Finance Party) (the
Sharing Finance Parties) in accordance with clause 33.5 (Partial payments) towards the
obligations of that Obligor to the Sharing Finance Parties. |
||
32.3 | Recovering Finance Party’s rights |
|
On a distribution by the Agent under clause 32.2 (Redistribution of payments) of a payment
received by a Recovering Finance Party from an Obligor, as between the relevant Obligor and
the Recovering Finance Party, an amount of the Recovered Amount equal to the Sharing Payment
will be treated as not having been paid by that Obligor. |
106
32.4 | Reversal of redistribution |
|
If any part of the Sharing Payment received or recovered by a Recovering Finance Party
becomes repayable and is repaid by that Recovering Finance Party, then: |
(a) | each Sharing Finance Party shall, upon request of the Agent, pay to the
Agent for the account of that Recovering Finance Party an amount equal to the
appropriate part of its share of the Sharing Payment (together with an amount as is
necessary to reimburse that Recovering Finance Party for its proportion of any
interest on the Sharing Payment which that Recovering Finance Party is required to
pay) (the Redistributed Amount); and |
||
(b) | as between the relevant Obligor and each relevant Sharing Finance Party, an
amount equal to the relevant Redistributed Amount will be treated as not having been
paid by that Obligor. |
32.5 | Exceptions |
|
32.5.1 | This clause 32 shall not apply to the extent that the Recovering Finance Party would not,
after making any payment pursuant to this clause, have a valid and enforceable claim against
the relevant Obligor. |
|
32.5.2 | A Recovering Finance Party is not obliged to share with any other Finance Party any amount
which the Recovering Finance Party has received or recovered as a result of taking legal or
arbitration proceedings in accordance with the terms of this Agreement, if: |
(a) | it notified that other Finance Party of the legal or arbitration
proceedings; and |
||
(b) | that other Finance Party had an opportunity to participate in those legal
or arbitration proceedings but did not do so as soon as reasonably practicable having
received notice and did not take separate legal or arbitration proceedings. |
107
33 | Payment mechanics |
|
33.1 | Payments to the Agent |
|
33.1.1 | On each date on which an Obligor or a Lender is required to make a payment under a Finance
Document, that Obligor or Lender shall make the same available to the Agent (unless a
contrary indication appears in a Finance Document) for value on the due date at the time and
in such funds specified by the Agent as being customary at the time for settlement of
transactions in the relevant currency in the place of payment. |
|
33.1.2 | Payment shall be made to such account in the principal financial centre of the country of
that currency (or, in relation to euro, in a principal financial centre in a Participating
Member State or London) with such bank as the Agent specifies. |
|
33.2 | Distributions by the Agent |
|
Each payment received by the Agent under the Finance Documents for another Party shall,
subject to clause 33.3 (Distributions to an Obligor) and clause 33.4 (Clawback) be made
available by the Agent as soon as practicable after receipt to the Party entitled to receive
payment in accordance with this Agreement (in the case of a Lender, for the account of its
Facility Office), to such account as that Party may notify to the Agent by not less than five
Business Days’ notice with a bank in the principal financial centre of the country of that
currency (or, in relation to euro, in the principal financial centre of a Participating
Member State or London). |
||
33.3 | Distributions to an Obligor |
|
The Agent may (with the consent of the Obligor or in accordance with clause 34 (Set-off))
apply any amount received by it for that Obligor in or towards payment (on the date and in
the currency and funds of receipt) of any amount due from that Obligor under the Finance
Documents or in or towards purchase of any amount of any currency to be so applied. |
||
33.4 | Clawback |
|
33.4.1 | Where a sum is to be paid to the Agent under the Finance Documents for another Party, the
Agent is not obliged to pay that sum to that other Party (or to enter into or perform any
related exchange contract) until it has been able to establish to its satisfaction that it
has actually received that sum. |
108
33.4.2 | If the Agent pays an amount to another Party and it proves to be the case that the Agent had
not actually received that amount, then the Party to whom that amount (or the proceeds of any
related exchange contract) was paid by the Agent shall on demand refund the same to the Agent
together with interest on that amount from the date of payment to the date of receipt by the
Agent, calculated by the Agent to reflect its cost of funds. |
|
33.5 | Partial payments |
|
33.5.1 | If the Agent receives a payment for application against amounts due under the Finance
Documents that is insufficient to discharge all the amounts then due and payable by an
Obligor under those Finance Documents, the Agent shall apply that payment towards the
obligations of that Obligor under those Finance Documents in the following order: |
(a) | first, in or towards payment pro rata of any unpaid fees, costs and
expenses (ignoring any fees payable under clause 11 (Fees)) of the Agent, the
Security Agent or the Arranger under those Finance Documents; |
||
(b) | secondly, in or towards payment to the Lenders pro-rata of any amount owing
to the Lenders under clause 30.10 (Lenders’ indemnity to the Agent) including any
amount resulting from the indemnity to the Security Agent under clause 30.19.1
(Application of certain clauses to Security Agent); |
||
(c) | thirdly, in or towards payment to the Lenders pro-rata of any accrued
interest, fee or commission due but unpaid under this Agreement or under any other
Finance Documents which are attributable to the Facility; |
||
(d) | fourthly, in or towards payment to the Lenders pro-rata of any principal
which is due but unpaid under those Finance Documents which are attributable to the
Facility; and |
||
(e) | fifthly, in or towards payment to the Lenders pro-rata of any accrued
interest, fee or commission due but unpaid under the Beta Facility Agreement or under
any other Finance Documents which are attributable to the Beta Facility Agreement; |
||
(f) | sixthly, in or towards payment to the Lenders pro-rata of any principal
which is due but unpaid under the Beta Facility Agreement or under any other Finance
Documents which are attributable to the Beta Facility Agreement; and |
||
(g) | seventhly, in or towards payment pro-rata of any other sum due but unpaid
under the Finance Documents. |
33.5.2 | The Agent shall, if so directed by all the Lenders, vary the order set out in paragraphs (b) to (g) of clause 33.5.1. |
|
33.5.3 | Clauses 33.5.1 and 33.5.2 above will override any appropriation made by an Obligor. |
109
33.6 | No set-off by Obligors |
|
All payments to be made by an Obligor under the Finance Documents shall be calculated and be
made without (and free and clear of any deduction for) set-off or counterclaim. |
||
33.7 | Business Days |
|
33.7.1 | Any payment which is due to be made on a day that is not a Business Day shall be made on
the next Business Day in the same calendar month (if there is one) or the preceding Business
Day (if there is not). |
|
33.7.2 | During any extension of the due date for payment of any principal or Unpaid Sum under this
Agreement interest is payable on the principal or Unpaid Sum at the rate payable on the
original due date. |
|
33.8 | Payments on demand |
|
For the purposes of clause 27.1 (Events of Default) and subject to the Agent’s right to
demand interest under clause 8.3, payments on demand shall be treated as paid when due if
paid within three Business Days of demand. |
||
33.9 | Currency of account |
|
33.9.1 | Subject to clauses 33.9.2 to 33.9.3, dollars is the currency of account and payment for any
sum due from an Obligor under any Finance Document. |
|
33.9.2 | A repayment of all or part of the Loan or an Unpaid Sum and each payment of interest shall
be made in dollars on its due date. |
|
33.9.3 | Each payment in respect of the amount of any costs, expenses or Taxes or other losses shall
be made in dollars and, if they were incurred in a currency other than dollars, the amount
payable under the Finance Documents shall be the equivalent in dollars of the relevant amount
in such other currency on the date on which it was incurred. |
|
33.9.4 | All moneys received or held by the Security Agent or by a Receiver under a Security
Document in a currency other than dollars may be sold for dollars and the Obligor which
executed that Security Document shall indemnify the Security Agent against the full cost in
relation to the sale. Neither the Security Agent nor such Receiver will have any liability
to that Obligor in respect of any loss resulting from any fluctuation in exchange rates after
the sale. |
110
34 | Set-off |
|
A Finance Party may set off any matured obligation due from an Obligor under the Finance
Documents (to the extent beneficially owned by that Finance Party) against any matured
obligation owed by that Finance Party to that Obligor, regardless of the place of payment,
booking branch or currency of either obligation. If the obligations are in different
currencies, the Finance Party may convert either obligation at a market rate of exchange in
its usual course of business for the purpose of the set-off. |
||
35 | Notices |
|
35.1 | Communications in writing |
|
Any communication to be made under or in connection with the Finance Documents shall be made
in writing and, unless otherwise stated, may be made by fax or letter. |
||
35.2 | Addresses |
|
The address, and fax number (and the department or officer, if any, for whose attention the
communication is to be made) of each Obligor or Finance Party for any communication or
document to be made or delivered under or in connection with the Finance Documents is: |
(a) | in the case of any Obligor which is a Party, that identified with its name
in Schedule 1 (The original parties); |
||
(b) | in the case of any Obligor which is not a Party, that identified in any
Finance Document to which it is a party; |
||
(c) | in the case of the Security Agent, the Agent and any other original Finance
Party that identified with its name in Schedule 1 (The original parties); and |
||
(d) | in the case of each Lender or other Finance Party, that notified in writing
to the Agent on or prior to the date on which it becomes a Party in the relevant
capacity, |
or, in each case, any substitute address, fax number, or department or officer as an Obligor
or Finance Party may notify to the Agent (or the Agent may notify to the other Parties, if a
change is made by the Agent) by not less than five Business Days’ notice. |
||
35.3 | Delivery |
|
35.3.1 | Any communication or document made or delivered by one person to another under or in
connection with the Finance Documents will only be effective: |
(a) | if by way of fax, when received in legible form; or |
||
(b) | if by way of letter, when it has been left at the relevant address or five
Business Days after being deposited in the post postage prepaid in an envelope
addressed to it at that address; |
and, if a particular department or officer is specified as part of its address details
provided under clause 35.2 (Addresses), if addressed to that department or officer. |
111
35.3.2 | Any communication or document to be made or delivered to the Agent or the Security Agent
will be effective only when actually received by the Agent or the Security Agent and then
only if it is expressly marked for the attention of the department or officer identified in
Schedule 1 (The original parties) (or any substitute department or officer as the Agent or
the Security Agent shall specify for this purpose). |
|
35.3.3 | All notices from or to an Obligor shall be sent through the Agent. |
|
35.3.4 | Any communication or document made or delivered to the Borrower in accordance with this
clause will be deemed to have been made or delivered to each of the Obligors. |
|
35.4 | Notification of address and fax number |
|
Promptly upon receipt of notification of an address and fax number or change of address or
fax number pursuant to clause 35.2 (Addresses) or changing its own address or fax number, the
Agent shall notify the other Parties. |
||
35.5 | Electronic communication |
|
35.5.1 | Any communication to be made between the Agent and a Lender or the Security Agent under or
in connection with the Finance Documents may be made by electronic mail or other electronic
means, if the Agent and the relevant Lender or the Security Agent: |
(a) | agree that, unless and until notified to the contrary, this is to be an
accepted form of communication; |
||
(b) | notify each other in writing of their electronic mail address and/or any
other information required to enable the sending and receipt of information by that
means; and |
||
(c) | notify each other of any change to their address or any other such
information supplied by them. |
35.5.2 | Any electronic communication made between the Agent and a Lender or the Security Agent will
be effective only when actually received in readable form and in the case of any electronic
communication made by a Lender or the Security Agent to the Agent only if it is addressed in
such a manner as the Agent shall specify for this purpose. |
|
35.6 | English language |
|
35.6.1 | Any notice given under or in connection with any Finance Document shall be in English. |
112
35.6.2 | All other documents provided under or in connection with any Finance Document shall be: |
(a) | in English; or |
||
(b) | if not in English, and if so required by the Agent, accompanied by a
certified English translation and, in this case, the English translation will prevail
unless the document is a constitutional, statutory or other official document. |
36 | Calculations and certificates |
|
36.1 | Accounts |
|
In any litigation or arbitration proceedings arising out of or in connection with a Finance
Document, the entries made in the accounts maintained by a Finance Party are prima facie
evidence of the matters to which they relate. |
||
36.2 | Certificates and determinations |
|
Any certification or determination by the Agent of a rate or amount under any Finance
Document is, in the absence of manifest error, conclusive evidence of the matters to which it
relates. |
||
36.3 | Day count convention |
|
Any interest, commission or fee accruing under a Finance Document will accrue from day to day
and is calculated on the basis of the actual number of days elapsed and a year of 360 days
or, in any case where the practice in the Interbank Market differs, in accordance with that
market practice. |
||
37 | Partial invalidity |
|
If, at any time, any provision of the Finance Documents is or becomes illegal, invalid or
unenforceable in any respect under any law of any jurisdiction, neither the legality,
validity or enforceability of the remaining provisions nor the legality, validity or
enforceability of such provision under the law of any other jurisdiction will in any way be
affected or impaired. |
||
38 | Remedies and waivers |
|
No failure to exercise, nor any delay in exercising, on the part of any Finance Party, any
right or remedy under the Finance Documents shall operate as a waiver, nor shall any single
or partial exercise of any right or remedy prevent any further or other exercise or the
exercise of any other right or remedy. The rights and remedies provided in the Finance
Documents are cumulative and not exclusive of any rights or remedies provided by law. |
113
39 | Amendments and grant of waivers |
|
39.1 | Required consents |
|
39.1.1 | Subject to clause 39.2 (Exceptions) and unless the provisions of the Co-ordination
Agreement expressly provides otherwise, any term of the Finance Documents may be amended or
waived with the consent of the Agent (acting on the instructions of the Majority Lenders and,
if it affects the rights and obligations of the Security Agent or the Agent, the consent of
the Agent or the Security Agent) and any such amendment or waiver agreed or given by the
Agent will be binding on the other Finance Parties. |
|
39.1.2 | The Agent may (or, in the case of the Security Documents, instruct the Security Agent to)
effect, on behalf of any Finance Party, any amendment or waiver permitted by this clause. |
|
39.2 | Exceptions |
|
39.2.1 | An amendment, waiver or discharge or release that has the effect of changing or which
relates to: |
(a) | the definition of “Majority Lenders” in clause 1.1 (Definitions); |
||
(b) | the definition of “Last Availability Date” in clause 1.1 (Definitions); |
||
(c) | an extension to the date of payment of any amount under the Finance
Documents; |
||
(d) | a reduction in the amount of any payment of principal, interest, fees or
commission payable or the rate at which they are calculated; |
||
(e) | an increase in, or an extension of, any Commitment; |
||
(f) | a change to the Borrower or any other Obligor; |
||
(g) | any provision which expressly requires the consent or approval of all the
Lenders; |
||
(h) | clause 2.2 (Finance Parties’ rights and obligations), clause 28 (Changes to
the Lenders), clause 32.1 (Payments to Finance Parties) or this clause 39; |
||
(i) | the order of distribution under clause 33.5 (Partial payments); |
||
(j) | the order of distribution under clause 30.21 (Order of application); |
||
(k) | the currency in which any amount is payable under any Finance Document; |
||
(l) | the nature or scope of the Charged Property or the manner in which the
proceeds of enforcement of the Security Documents are distributed; |
114
(m) | the nature or scope of the guarantee and indemnity granted under clause 17
(Guarantee and Indemnity); |
||
(n) | the circumstances in which the security constituted by the Security
Documents are permitted or required to be released under any of the Finance
Documents, |
shall not be made without the prior consent of all the Lenders. |
||
39.2.2 | An amendment or waiver which relates to the rights or obligations of the Agent, the
Security Agent or the Arranger in their respective capacities as such (and not just as a
Lender) may not be effected without the consent of the Agent, Security Agent or the Arranger
(as the case may be). |
|
39.2.3 | Notwithstanding clauses 39.1 and 39.2.1 to 39.2.2 (inclusive), the Agent may make technical
amendments to the Finance Documents arising out of manifest errors on the face of the Finance
Documents, where such amendments would not prejudice or otherwise be adverse to the interests
of any Finance Party without any reference or consent of the Finance Parties. |
|
39.3 | Releases |
|
Except with the approval of the Lenders or as is expressly permitted or required by the
Finance Documents, the Agent shall not have authority to authorise the Security Agent to
release: |
(a) | any Charged Property from the security constituted by any Security
Document; or |
||
(b) | any Obligor from any of its guarantee or other obligations under any
Finance Document. |
40 | Counterparts |
|
Each Finance Document may be executed in any number of counterparts, and this has the same
effect as if the signatures on the counterparts were on a single copy of the Finance
Document. |
||
41 | Confidentiality |
|
41.1 | Confidential Information |
|
Each Finance Party agrees to keep all Confidential Information confidential and not to
disclose it to anyone, save to the extent permitted by clause 41.2 (Disclosure of
Confidential Information), and to ensure that all Confidential Information is protected with
security measures and a degree of care that would apply to its own confidential information. |
115
41.2 | Disclosure of Confidential Information |
|
Any Finance Party may disclose to any of its Affiliates and any other person: |
(a) | in the case of a Lender, to (or through) whom that Lender assigns (or may
potentially assign) all or any of its rights and obligations under the Finance
Documents; |
||
(b) | in the case of a Lender, with (or through) whom that Lender enters into (or
may potentially enter into) any sub-participation in relation to, or any other
transaction under which payments are to be made by reference to, the Finance
Documents or any Obligor; |
||
(c) | to whom, and to the extent that, information is required to be disclosed by
any applicable law or regulation; or |
||
(d) | to whom information is required or requested to be disclosed by any court
of competent jurisdiction or any governmental, banking, taxation or other regulatory
authority or similar body, the rules of any relevant stock exchange or pursuant to
any applicable law or regulation, |
and any Finance Party may disclose to a rating agency or its professional advisers or (with
the consent of the Borrower) any other person, any information about any Obligor, the Group
and the Finance Documents as that Finance Party shall consider appropriate. |
||
41.3 | Entire agreement |
|
This clause 41 (Confidentiality) constitutes the entire agreement between the Parties in
relation to the obligations of the Finance Parties under the Finance Documents regarding
Confidential Information and supersedes any previous agreement, whether express or implied,
regarding Confidential Information. |
||
41.4 | Inside information |
|
Each of the Finance Parties acknowledges that some or all of the Confidential Information is
or may be price-sensitive information and that the use of such information may be regulated
or prohibited by applicable legislation including securities law relating to insider dealing
and market abuse and each of the Finance Parties undertakes not to use any Confidential
Information for any unlawful purpose. |
116
41.5 | Notification of disclosure |
|
Each of the Finance Parties agrees (to the extent permitted by applicable law) to the
Borrower: |
(a) | of the circumstances of any disclosure of Confidential Information made
pursuant to clause 41.2 (Disclosure of Confidential Information) except where such
disclosure is made to any of the persons referred to in that clause during the
ordinary course of its supervisory or regulatory function; and |
||
(b) | upon becoming aware that Confidential Information has been disclosed in
breach of this clause 41 (Confidentiality). |
41.6 | Continuing obligations |
|
The obligations in this clause 41 (Confidentiality) are continuing and, in particular, shall
survive and remain binding on each Finance Party for a period of 12 months from the earlier
of: |
(a) | the date on which all amounts payable by the Obligors under or in
connection with this Agreement have been paid in full and all Commitments have been
cancelled or otherwise cease to be available; and |
||
(b) | the date on which such Finance Party otherwise ceases to be a Finance
Party. |
117
42 | Governing law |
|
This Agreement and any non-contractual obligations connected with it are governed by English
law. |
||
43 | Enforcement |
|
43.1 | Jurisdiction of English courts |
|
43.1.1 | The courts of England have exclusive jurisdiction to settle any dispute arising out of or
in connection with this Agreement or any non-contractual obligations connected with it
(including a dispute regarding the existence, validity or termination of this Agreement) (a
Dispute). |
|
43.1.2 | The Parties agree that the courts of England are the most appropriate and convenient courts
to settle Disputes and accordingly no Party will argue to the contrary. |
|
43.1.3 | This clause 43.1 is for the benefit of the Finance Parties only. As a result, no Finance
Party shall be prevented from taking proceedings relating to a Dispute in any other courts
with jurisdiction. To the extent allowed by law, the Finance Parties may take concurrent
proceedings in any number of jurisdictions. |
|
43.2 | Service of process |
|
Without prejudice to any other mode of service allowed under any relevant law, each Obligor
which is a Party: |
(a) | irrevocably appoints the person named in Schedule 1 (The original parties)
as that Obligor’s English process agent as its agent for service of process in
relation to any proceedings before the English courts in connection with any Finance
Document; |
||
(b) | agrees that failure by a process agent to notify the relevant Obligor of
the process will not invalidate the proceedings concerned; and |
||
(c) | if any person appointed as process agent for an Obligor is unable for any
reason to act as agent for service of process, that Obligor must immediately (and in
any event within ten days of such event taking place) appoint another agent on terms
acceptable to the Agent. Failing this, the Agent may appoint another agent for this
purpose. |
118
The original parties
Name:
|
Alpha Elephant Inc | |||
Jurisdiction of incorporation
|
Xxxxxxxx Islands | |||
Registration number (or equivalent, if
any)
|
39274 | |||
English process agent (if not incorporated in England) |
Ince Process Agents Ltd 0xx Xxxxx, Xxxxxxxxxxxxx Xxxxx, 0 Xx. Xxxxxxxxx’s Way, London E1W 1AY |
|||
Registered office
|
Trust Company Complex, Ajeltake
Road, Ajeltake Island, Majuro, Republic of Xxxxxxxx Xxxxxxx XX 00000 |
|||
Address for service of notices
|
Address: 00X, Xx. 000, Xxx 0,
Xxxxxx X Xxxx, Xxxxxx, Xxxxxx 106 Fax: x000 0 0000 0000 Attention: Xx. Xxxx Xxx Su |
Name of Parent
|
Solar VLCC Corporation | |||
Jurisdiction of incorporation
|
Xxxxxxxx Islands | |||
Registration number (or equivalent, if any) |
38165 | |||
English process agent (if not incorporated in England) |
Ince Process Agents Ltd 0xx Xxxxx, Xxxxxxxxxxxxx Xxxxx, 0 Xx. Xxxxxxxxx’s Way, London E1W 1AY |
|||
Registered office
|
Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Republic of Xxxxxxxx Xxxxxxx XX 00000 |
|||
Address for service of
notices
|
Address: 00X, Xx. 000, Xxx 0, Xxxxxx X Xxxx, Xxxxxx, Xxxxxx 106 Fax: x000 0 0000 0000 Attention: Xx. Xxxx Xxx Su |
119
Name of Beta Guarantor
|
Beta Elephant Inc. | |||
Jurisdiction of incorporation
|
Xxxxxxxx Islands | |||
Registration number (or equivalent, if
any)
|
39275 | |||
English process agent (if not incorporated in England) |
Ince Process Agents Ltd 0xx Xxxxx, Xxxxxxxxxxxxx Xxxxx, 0 Xx. Xxxxxxxxx’s Way, London E1W 1AY |
|||
Registered office
|
Trust Company Complex, Ajeltake
Road, Ajeltake Island, Majuro, Republic of Xxxxxxxx Xxxxxxx XX 00000 |
|||
Address for service of notices
|
Address: 00X, Xx. 000, Xxx 0,
Xxxxxx X Xxxx, Xxxxxx, Xxxxxx 106 Fax: x000 0 0000 0000 Attention: Xx. Xxxx Xxx Xx |
Name of Xxxx
|
Xxxx Venture Ltd. | |
Jurisdiction of incorporation
|
Liberia | |
English process agent (if not incorporated in England) |
Ince Process Agents Ltd 0xx Xxxxx, Xxxxxxxxxxxxx Xxxxx, 0 Xx. Xxxxxxxxx’s Way, London E1W 1AY |
|
Registered office
|
00 Xxxxx Xxxxxx, Xxxxxxxx, Xxxxxxx | |
Address for service of notices
|
Address: 00X, Xx. 000, Xxx 0, Xxxxxx X
Xxxx, Xxxxxx, Xxxxxx 106 Fax: x000 0 0000 0000 Attention: Xx. Xxxx Xxx Su |
120
The Original Lenders | ||||
Name
|
Deutsche Bank AG, London Branch | |||
Commitment $ |
57,500,000 | |||
Facility office, address, fax number
and attention details for notices
|
0 Xxxxx Xxxxxxxxxx Xxxxxx Xxxxxx XX0X 0XX Fax: x00 000 000 0000 Attention: Xxxxx Xxxxx/Xxxxxxx Kirreh |
|||
TOTAL
|
57,500,000 |
121
Name
|
Deutsche Bank Luxembourg S.A. | |
Facility Office, address, fax
number and attention details
for notices
|
0, Xxxxxxxxx Xxxxxx Xxxxxxxx X-0000 Xxxxxxxxxx Fax: x000 000 00000/552 Attention: Banu Ozkutan/Xxxxx-Xxxxx Ewerhardy, International Loans and Agency Services |
Name
|
Deutsche Bank AG, London Branch | |
Facility Office, address, fax number
and attention details for notices
|
0 Xxxxx Xxxxxxxxxx Xxxxxx Xxxxxx XX0X 0XX Fax: x00 000 000 0000 Attention: Xxxxx Xxxxx/Xxxxxxx Kirreh |
Name
|
Deutsche Bank Luxembourg S.A. | |
Facility Office, address, fax
number and attention details
for notices
|
0, Xxxxxxxxx Xxxxxx Xxxxxxxx X-0000 Xxxxxxxxxx Fax: x000 000 00000/552 Attention: Banu Ozkutan/Xxxxx-Xxxxx Ewerhardy, International Loans and Agency Services |
122
Ship information
Builder’s Name
|
Daewoo Shipbuilding & Marine Engineering Co., Ltd. | |
Hull Number
|
Hull No. 5330 | |
Date and description
of Building Contract:
|
Shipbuilding contract dated 8 May 2007 and made between K Elephant Corporation and the Builder (as novated to A Elephant Inc and as further novated to Alpha Elephant Inc as amended and supplemented by Xxxxxxxx Xx 0 (xxx Xxxxxxxx Xxxxxxxx Addendum) dated on or about the date hereof providing for a deferral of the Contract Price in the sum of the aggregate of (a) $25,000,000 (Deferred Instalment I) and (b) $30,000,000 (Deferred Instalment II) and as further amended and/or supplemented from time to time) | |
Contract Price:
|
$ 133,198,497 | |
Flag State:
|
Xxxxxxxx Islands | |
Classification:
|
as set out in Article I.3 of the Building Contract | |
Classification Society:
|
Lloyds Register of Shipping | |
Major Casualty Amount
|
$1,000,000 | |
Commercial Manager
|
Blue Whale Corporation |
Builder’s Name
|
Daewoo Shipbuilding & Marine Engineering Co., Ltd. | |
Hull Number
|
Hull No. 5327 | |
Date and description
of Building Contract:
|
Shipbuilding contract dated 1 December 2006 and made between H Elephant Corporation and the Builder (as novated to B Elephant Inc and as further novated to Beta Elephant Inc and as amended and/or supplemented from time to time) | |
Flag State:
|
Xxxxxxxx Islands | |
Commercial Manager
|
Blue Whale Corporation |
123
Conditions precedent
Conditions precedent to Utilisation
1 | Obligors’ corporate documents |
(a) | A copy of the Constitutional Documents of each Obligor. |
||
(b) | A copy of a resolution of the board of directors of each Obligor: |
(i) | approving the terms of, and the transactions contemplated by, the
Finance Documents to which it is a party and resolving that it execute the Finance
Documents; |
||
(ii) | authorising a specified person or persons to execute the Finance
Documents on its behalf; and |
||
(iii) | authorising a specified person or persons, on its behalf, to sign
and/or despatch all documents and notices (including, if relevant, any Utilisation
Request) to be signed and/or despatched by it under or in connection with the
Finance Documents to which it is a party. |
(c) | A specimen of the signature of each person authorised by the resolution referred
to in paragraph (b) above. |
||
(d) | A copy of a resolution signed by all the holders of the issued shares in each
Obligor, approving the terms of, and the transactions contemplated by, the Finance
Documents to which such Obligor is a party. |
||
(e) | A copy of a resolution of the board of directors of each corporate shareholder of
each Obligor approving the terms of the resolution referred to in paragraph (d) above. |
||
(f) | A certificate of the Parent (signed by a director) confirming that borrowing or
guaranteeing or securing, as appropriate, the Total Commitments would not cause any
borrowing, guaranteeing or similar limit binding on any Obligor to be exceeded. |
||
(g) | A copy of any power of attorney under which any person is to execute any of the
Finance Documents on behalf of any Obligor. |
||
(h) | A certificate of an authorised signatory of the relevant Obligor certifying that
each copy document relating to it specified in this Part of this Schedule is correct,
complete and in full force and effect as at a date no earlier than the date of this
Agreement and that any such resolutions or power of attorney have not been revoked. |
124
2 | Other documents and evidence |
(a) | Evidence that any process agent referred to in clause 43.2 (Service of process)
or any equivalent provision of any other Finance Document entered into on or before the
Utilisation Date has accepted its appointment. |
||
(b) | A copy of any other authorisation or other document, opinion or assurance which
the Arranger considers to be necessary or desirable (if it has notified the Borrower
accordingly) in connection with the entry into and performance of the transactions
contemplated by any Finance Document or for the validity and enforceability of any
Finance Document. |
||
(c) | A statement from the Obligors regarding their financial position in a form and
substance acceptable to the Agent (acting on the instructions of the Majority Lenders). |
||
(d) | The Co-ordination Agreement duly executed by all parties to it other than the
Security Agent. |
||
(e) | The Beta Guarantee duly executed by the Beta Guarantor. |
||
(f) | The Fee Letters duly executed and evidence that the fees, commissions, costs and
expenses then due from the Borrower pursuant to clause 11 (Fees) and clause 16 (Costs
and expenses) have been paid or will be paid by the Utilisation Date. |
3 | Building Contract |
|
A copy, certified by an approved person to be a true and complete copy, of the Building
Contract (including the Building Contract Addendum), the Beta Building Contract (including
the Beta Building Contract Addendum) and the MOU, each to be in an approved form. |
||
4 | Junior Security Documents |
|
A copy of each of the Junior Security Documents, duly executed by the parties thereto. |
||
5 | “Know your customer” information |
|
Such documentation and information as any Finance Party may reasonably request through the
Agent to comply with “know your customer” or similar identification procedures under all laws
and regulations applicable to that Finance Party. |
125
Conditions precedent on Delivery
1 | Corporate documents |
(a) | A certificate of an authorised signatory of the Borrower certifying that each
copy document relating to it specified in Part 1 of this Schedule remains correct,
complete and in full force and effect as at a date no earlier than a date approved for
this purpose and that any resolutions or power of attorney referred to in Part 1 of this
Schedule in relation to it have not been revoked or amended. |
||
(b) | A certificate of an authorised signatory of each other Obligor which is party to
any of the Security Documents required to be executed at or before Delivery of the Ship
certifying that each copy document relating to it specified in Part 1 of this Schedule
remains correct, complete and in full force and effect as at a date no earlier than a
date approved for this purpose and that any resolutions or power of attorney referred to
in Part 1 of this Schedule in relation to it have not been revoked or amended. |
2 | Security |
(a) | The Mortgage, the General Assignment and if the Beta Ship shall have been
delivered to the Beta Guarantor, the remaining Beta Security Documents each duly
executed. |
||
(b) | Any Manager’s Undertaking then required pursuant to the Finance Documents duly
executed by the relevant manager. |
||
(c) | Duly executed notices of assignment and acknowledgements of those notices as
required by any of the above Security Documents. |
||
(d) | The Share Security in respect of the Borrower duly executed by the Parent
together with all letters, transfers, certificates and other documents required to be
delivered under the Share Security. |
3 | Bank Accounts |
|
Evidence that any Account required to be established under clause 25 (Bank accounts) has been
opened and established, that any Account Security in respect of each such Account has been
executed and delivered by the Borrower or, as the case may be, the Parent in favour of the
Security Agent and that any notice required to be given to an Account Bank under that Account
Security has been given to it and acknowledged by it in the manner required by that Account
Security and that a minimum cash amount of $2,500,000 has been deposited in the Debt Service
Reserve Account. |
126
4 | Delivery and registration of Ship |
|
Evidence that the Ship: |
(i) | is legally and beneficially owned by the Borrower and registered in
the name of the Borrower through the relevant Registry as a ship under the laws
and flag of the relevant Flag State; |
||
(ii) | is operationally seaworthy and in every way fit for service; |
||
(iii) | is classed with the relevant Classification free of all requirements
and recommendations of the relevant Classification Society; |
||
(iv) | is insured in the manner required by the Finance Documents; |
||
(v) | is free of any charter commitment which would require approval under
the Finance Documents. |
5 | Mortgage registration |
|
Evidence that the Mortgage has been registered against the Ship through the relevant Registry
under the laws and flag of the relevant Flag State. |
||
6 | Legal opinions |
(a) | A legal opinion of Xxxxxx Xxxx LLP, 3 More Xxxxxx Xxxxxxxxx, Xxxxxx XX0 0XX,
addressed to the Arranger, the Security Agent and the Agent on matters of English law,
substantially in the form approved by the Arranger prior to signing this Agreement. |
||
(b) | A legal opinion of the legal advisers to the Arranger, the Security Agent and the
Agent in each jurisdiction in which an Obligor is incorporated and/or which is or is to
be the Flag State of the Ship, or in which an Account opened at Utilisation is
established substantially in the form approved by the Arranger prior to signing this
Agreement. |
7 | Contract price |
(a) | Confirmation from the Builder that any amount of the Contract Price which
is not to be financed by the Loan has been paid or deferred pursuant to the Building
Contract Addendum. |
||
(b) | The Effective Date Notice (as defined in the Building Contract Addendum)
duly issued under the Building Contract Addendum. |
127
8 | Insurance |
|
In relation to the Ship’s Insurances: |
(a) | an opinion from insurance consultants appointed by the Arranger on such
Insurances; |
||
(b) | evidence that such Insurances have been placed in accordance with clause 23
(Insurance); and |
||
(c) | evidence that approved brokers, insurers and/or associations have issued or will
issue letters of undertaking in favour of the Security Agent in an approved form in
relation to the Insurances. |
9 | ISM and ISPS Code |
|
Copies of: |
(a) | the document of compliance issued in accordance with the ISM Code to the person
who is the operator of the Ship for the purposes of that code; |
||
(b) | the safety management certificate in respect of the Ship issued in accordance
with the ISM Code; |
||
(c) | the international ship security certificate in respect of the Ship issued under
the ISPS Code; and |
||
(d) | if so requested by the Arranger, any other certificates issued under any
applicable code required to be observed by the Ship or in relation to its operation
under any applicable law. |
10 | Construction matters |
(a) | Evidence that any authorisations required from any government entity for the
export of the Ship by the Builder have been obtained or that no such authorisations are
required. |
||
(b) | The original or a copy, certified by an approved person to be a true and complete
copy, of the builder’s certificate and any xxxx of sale conveying title to the Ship to
the Borrower and the protocol of delivery and acceptance, commercial invoice and any
other delivery documentation required under the Building Contract. |
11 | Fees and expenses |
|
Evidence that the fees, commissions, costs and expenses that are due from the Borrower
pursuant to clause 11 (Fees) and clause 16 (Costs and expenses) have been paid or will be
paid by the Utilisation Date. |
128
12 | Survey report |
|
A survey report from approved surveyors obtained not more than ten days before the
Utilisation Date evidencing that the Ship is seaworthy and capable of safe operation. |
||
13 | Environmental matters |
|
Copies of the Ship’s certificate of financial responsibility and vessel response plan
required under United States law and evidence of their approval by the appropriate United
States government entity (or if the Ship shall not trade to the United States of America from
the Delivery Date, a letter from the Borrower confirming that it will obtain the same prior
to trading the Ship to the United States of America) and (if requested by the Arranger) an
environmental report in respect of the Ship from an approved person. |
||
14 | Management Agreement |
|
A copy, certified by an approved person to be a true and complete copy, of any agreement
between the Borrower and any Manager relating to the appointment of that Manager. |
129
Utilisation Request
From:
|
Alpha Elephant Inc. | |
To:
|
Deutsche Bank Luxembourg S.A. | |
Dated:
|
[l] 2010 |
1 | We refer to the Agreement. This is a Utilisation Request. Terms defined in the Agreement
have the same meaning in this Utilisation Request unless given a different meaning in this
Utilisation Request. |
|
2 | We wish to borrow the Loan on the following terms: |
Proposed Utilisation Date:
|
[l] (or, if that is not a Business Day, the next Business Day) | |
Amount:
|
$ [l] |
3 | We confirm that each condition specified in clause 4.4 (Further conditions precedent) is
satisfied on the date of this Utilisation Request. |
|
4 | The purpose of the Loan is [specify purpose complying with clause 3 of the Agreement] and its
proceeds should be credited to [l] [specify account including swift code]. |
|
5 | We acknowledge that the first Interest Period shall expire on [31 July 2010] [31 October
2010] [31 January 2011] [30 April 2011]. |
|
6 | This Utilisation Request is irrevocable. |
130
Form of Transfer Certificate
To:
|
Deutsche Bank Luxembourg S.A. as Agent | |
From:
|
[The Existing Lender] (the Existing Lender) and [The New Lender] (the New Lender) | |
Dated: |
1 | We refer to the Agreement. This is a Transfer Certificate. Terms defined in the Agreement
have the same meaning in this Transfer Certificate unless given a different meaning in this
Transfer Certificate. |
|
2 | We refer to clause 28.5 (Procedure for transfer): |
(a) | The Existing Lender and the New Lender agree to the Existing Lender assigning to
the New Lender all or part of the Existing Lender’s Commitment rights and assuming the
Existing Lender’s obligations referred to in the Schedule in accordance with clause 28.5
(Procedure for transfer) and the Existing Lender assigns and agrees to assign such
rights to the New Lender with effect from the Transfer Date] |
||
(b) | The proposed Transfer Date is [•]. |
||
(c) | The Facility Office and address, fax number and attention details for notices of
the New Lender for the purposes of clause 35.2 (Addresses) are set out in the Schedule. |
3 | The New Lender expressly acknowledges the limitations on the Existing Lender’s obligations
set out in clause 28.4.3 (Limitation of responsibility of Existing Lenders). |
|
4 | This Transfer Certificate may be executed in any number of counterparts and this has the same
effect as if the signatures on the counterparts were on a single copy of this Transfer
Certificate. |
|
This Transfer Certificate and any non-contractual obligations connected with it are governed
by English law. |
131
Commitment/rights to be assigned and obligations to be assumed
[insert relevant details]
Facility Office address, fax number
and attention details for notices and account details for payments
[insert relevant details]
[Existing Lender]
|
[New Lender] | |
By: _________________________
|
By: _________________________ |
132
Approved Technical Managers
133
Form of Technical Management Agreement
134
THE BORROWER | ||||
ALPHA ELEPHANT INC | ||||
By: |
||||
THE PARENT | ||||
SOLAR VLCC CORPORATION | ||||
By: |
||||
THE ARRANGER | ||||
DEUTSCHE BANK AG, LONDON BRANCH | ||||
By: |
||||
THE AGENT | ||||
DEUTSCHE BANK LUXEMBOURG S.A. | ||||
By: |
||||
THE SECURITY AGENT | ||||
DEUTSCHE BANK LUXEMBOURG S.A. | ||||
By: |
||||
THE LENDERS | ||||
DEUTSCHE BANK AG, LONDON BRANCH | ||||
By: |
||||
135