EXHIBIT 10.22
OFFICE LEASE
by and between
ALZA CORPORATION
and
CHEMDEX CORPORATION
for space at
1500 and 0000 XXXXXXXX XXXXXX
XXXXXXXX XXXX, XXXXXXXXXX
August 13, 1999
TABLE OF CONTENTS
BASIC LEASE PROVISIONS ...................................................................................... 1
1. DEFINITIONS ............................................................................................. 2
2. TERM AND POSSESSION ..................................................................................... 5
3. MONTHLY BASE RENT; NET LEASE ............................................................................ 8
4. LETTER OF CREDIT ........................................................................................ 9
5. TENANT'S PAYMENT OF PROPERTY TAXES AND INSURANCE PREMIUMS ............................................... 10
6. MAINTENANCE, REPAIR AND REPLACEMENT ..................................................................... 12
7. IMPROVEMENTS AND ALTERATIONS; LIENS ..................................................................... 13
8. USE OF PREMISES ......................................................................................... 16
9. HAZARDOUS MATERIALS ..................................................................................... 17
10. UTILITIES AND SERVICES .................................................................................. 20
11. RULES AND REGULATIONS ................................................................................... 21
12. TAXES ON TENANT'S PROPERTY .............................................................................. 21
13. FIRE OR CASUALTY ........................................................................................ 22
14. EMINENT DOMAIN .......................................................................................... 23
15. ASSIGNMENT AND SUBLETTING ............................................................................... 25
16. ACCESS AND RESERVED RIGHTS .............................................................................. 29
17. SUBORDINATION AND ATTORNMENT ............................................................................ 30
18. TRANSFER OF PREMISES; QUIET ENJOYMENT ................................................................... 31
19. NONLIABILITY AND INDEMNIFICATION OF LANDLORD; INSURANCE ................................................. 32
20. WAIVER OF SUBROGATION ................................................................................... 35
21. ATTORNEYS' FEES ......................................................................................... 35
22. WAIVER .................................................................................................. 36
23. NOTICES ................................................................................................. 36
24. BANKRUPTCY .............................................................................................. 36
25. DEFAULT AND REMEDIES .................................................................................... 37
26. HOLD OVER ............................................................................................... 41
27. CONDITION OF PREMISES ................................................................................... 41
28. QUIET POSSESSION ........................................................................................ 41
29. DAMAGE TO TENANT'S PROPERTY ............................................................................. 41
30. CONFLICT OF LAWS ........................................................................................ 42
31. SUCCESSORS AND ASSIGNS .................................................................................. 42
32. BROKERS ................................................................................................. 42
33. NEGOTIATED AGREEMENT .................................................................................... 43
34. INTEREST ON TENANTS OBLIGATIONS; LATE CHARGE ............................................................ 43
35. TIME .................................................................................................... 43
36. DEFINED TERMS AND MARGINAL HEADINGS ..................................................................... 44
37. PRIOR AGREEMENTS ........................................................................................ 44
38. AUTHORITY OF PARTIES .................................................................................... 44
39. NO LIGHT, AIR OR VIEW EASEMENT .......................................................................... 45
40. EXAMINATION OF LEASE .................................................................................... 45
41. FORCE MAJEURE ........................................................................................... 45
42. RECORDING ............................................................................................... 45
43. INCORPORATION BY REFERENCE .............................................................................. 46
44. DEFINITION OF ADDITIONAL RENT ................................................................................46
45. SURRENDER OF PREMISES ........................................................................................46
46. NO ACCORD AND SATISFACTION ...................................................................................47
47. MERGER .......................................................................................................47
48. FINANCIAL STATEMENTS .........................................................................................47
EXHIBITS AND SCHEDULES
----------------------
A. Legal Description
B. Schedule of Monthly Base Rent
C. Letter of Credit
D. Work Letter for Tenant Improvements
E. Nondisturbance Agreement
1. List of Remaining Furniture
2. List of Groundwater Monitoring Report
LEASE
THIS LEASE ("Lease") is made this 13/th/ day of August, 1999 by and
between ALZA CORPORATION, a Delaware Corporation ("Landlord"), and CHEMDEX
CORPORATION, a Delaware corporation ("Tenant").
Landlord hereby leases to Tenant and Tenant hereby hires from
Landlord, subject to all of the terms and conditions hereinafter set forth,
those certain premises described in Item 6 of the Basic Lease Provisions and
located at 1500 and 0000 Xxxxxxxx Xxxxxx, Xxxxxxxx Xxxx, Xxxxxxxxxx.
BASIC LEASE PROVISIONS
----------------------
1. Date: August 13, 1999
----
2. Tenant: CHEMDEX CORPORATION, a Delaware corporation
------
3. Address: Before Commencement Date:
-------
0000 Xxxxxx Xxx
Xxxx Xxxx, Xxxxxxxxxx 00000
Attention: Xxxxx Xxxxxx, Director of Corporate Operations
After Commencement Date:
0000 Xxxxxxxx Xxxxxx
Xxxxxxxx Xxxx, Xxxxxxxxxx 00000
Attention: Xxxxx Xxxxxx, Director of Corporate Operations
4. Landlord: ALZA CORPORATION, a Delaware corporation
--------
5. Address: 950 Page Mill Road
-------
Xxxx Xxxx, Xxxxxxxxxx 00000
Attention: Senior Vice President and General Counsel
6. Premises: The two-story freestanding building located at 0000 Xxxxxxxx
Xxxxxx, Xxxxxxxx Xxxx, Xxxxxxxxxx containing approximately
40,000 rentable square feet ("RSF") and the two-story
freestanding building located at 0000 Xxxxxxxx Xxxxxx,
Xxxxxxxx Xxxx, Xxxxxxxxxx also containing approximately
40,000 RSF, together with the parking areas, driveways,
landscaping, common areas and other appurtenances
constructed or located on or serving the 1500 and 0000
Xxxxxxxx Xxxxxx buildings (the "Premises"). The real
property on which the Premises is located is more
particularly described in Exhibit A attached hereto and
---------
incorporated herein by this reference
7. Term: Approximately five (5) years and four (4) months (See
----
Article 2)
8. Monthly Base Rent: The following Monthly Base Rent for the
-----------------
Premises shall be payable on a triple net basis
pursuant to Section 3.1 below: From the Commencement
Date until October 14, 2000, Two Hundred Twenty-Eight
Thousand Dollars ($228,000) per month. The Monthly
Base Rent for the remaining Lease years during the
Term and each Extended Term (if any) of this Lease
shall be as set forth on Exhibit B attached hereto and
---------
incorporated herein by this reference. Monthly Base
Rent for the Premises (but no other rent or charges
due under this Lease) shall be forgiven for the first
month of the Term.
9. Prepaid Rent: $228,000 due upon execution of the Lease by Landlord
------------
and Tenant (See Section 3.1)
10. Letter of Credit: Letter of Credit in the amount of One Million Eight
----------------
Hundred Seventy-Five Thousand Dollars ($1,875,000) due
upon execution of the Lease (See Article 4)
11. Permitted Use: As provided in Article 8
-------------
12. Renewal Options: Subject to Landlord's Recapture Right (defined in
---------------
Section 2.3 below), two (2) successive one (1) year
renewal options (See Section 2.3)
13. Expansion Options: None
------------------
14. Landlord's Broker: Catalyst-CRESA Real Estate Group
-----------------
15. Tenant's Broker: Cornish & Xxxxx Commercial Real Estate
---------------
The foregoing Basic Lease Provisions set forth the essential terms of
this Lease and should be read in conjunction with the rest of the Lease and in
particular, with reference to how those terms are defined in the Lease.
ARTICLE 1
DEFINITIONS
-----------
Unless otherwise specified, the following terms used in this Lease and
designated by initial capitals shall have the following meanings:
1.1 "Environmental Laws" shall mean all local, state, or federal laws,
------------------
statutes, ordinances, rules, regulations, judgments, injunctions, stipulations,
decrees, orders, policies, permits, approvals, treaties, or protocols now or
hereafter enacted, issued or promulgated by any governmental authority which
relate to any Hazardous Material or the use, manufacture, handling, treatment,
transportation, production, disposal, discharge, distribution, release,
recycling, emission, sale, or storage of, or the exposure of any person to, a
Hazardous Material.
1.2 "Financial Statements" shall mean the financial information contained
--------------------
in Tenant's Initial Registration Statement on Form S-1 accessed by Landlord on
or about May 24, 1999 at xxx.xxxxxxxxx.xxx.
1.3 "Force Majeure" shall mean any of the events described in Article 41,
-------------
below.
1.4 "Hazardous Material" shall mean any material or substance that is now
------------------
or hereafter prohibited or regulated by any statute, law, rule, regulation or
ordinance or that is now or hereafter designated by any governmental authority
to be radioactive, toxic, hazardous or otherwise a danger to health,
reproduction or the environment including but not limited to (i) oil and
petroleum products, (ii) radioactive materials, (iii) asbestos and asbestos-
containing materials, (iv) polycholorinated biphenyls, and (v) viruses, microbes
and other biological materials and (v) substances defined as "hazardous
substances", "hazardous materials", or "toxic substances" in the Comprehensive
Environmental Response Compensation and Liability Act of 1980, as amended, 42
U.S.C. (S)(S)9601 et seq.; the Hazardous Materials Transportation Act, 49 U.S.C.
-- ---
(S)(S) 1801 et seq.; the Resource Conservation and Recovery Act, 42 U.S.C.
-- ---
(S)(S) 6901, et seq.; the Toxic Substances Control Act, 15 U.S.C. (S)(S) 2601,
-- ---
et seq.; the Clean Water Act, 33 U.S.C. (S)(S) 1251, et seq.; the California
-- --- -- ---
Hazardous Waste Control Act, Health and Safety Code (S)(S) 25330, et seq.; the
-- ---
California Safe Drinking Water and Toxic Enforcement Act, Health and Safety Code
(S)(S) 25249.5, et seq.; California Health and Safety Code (S)(S) 25280, et seq.
-- --- -- ---
(Underground Storage of Hazardous Substances); the California Hazardous Waste
Management Act, Health and Safety Code, (S)(S) 25170, et seq. (Hazardous
-- ---
Materials Release Response Plans and Inventory); the California Xxxxxx-Cologne
Water Quality Control Act, Water Code (S)(S) 13000, et seq.; all as amended.
-- ---
1.5 "Hazardous Material Condition" shall mean the occurrence or discovery,
----------------------------
after the Commencement Date, of a condition involving the presence of, or a
contamination by, a Hazardous Material in or under the Premises requiring
remediation under Environmental Laws or rendering any part of the Premises
unsafe for human occupancy.
1.6 "Xxxxxxx Lease" shall mean the office lease of even date herewith
-------------
executed by Landlord and Tenant for the Xxxxxxx Premises.
1.7 "Xxxxxxx Premises" shall mean the second floor of the two-story
----------------
freestanding building located at 0000 Xxxxxxx Xxxx, Xxxxxxxx Xxxx, Xxxxxxxxxx,
containing approximately 26,445 RSF together with the shared parking areas,
driveways, landscaping, common areas and other appurtenances constructed or
located thereon.
1.8 "Landlord Affiliate" shall mean any corporation, general or limited
------------------
partnership, joint venture, limited liability company or other person or entity
which controls, is controlled by or under common control with ALZA Corporation
or resulting from a merger or consolidation with ALZA Corporation or which
acquires substantially all of the assets of ALZA Corporation.
1.9 "Landlord Parties" shall mean Landlord, its employees, agents,
----------------
consultants, licensees, invitees, contractors, subcontractors, and any other
person for whom Landlord is legally responsible, provided that under no
circumstances shall any of Tenant Parties be deemed a Landlord Party for
purposes of this Lease.
1.10 "Lease" shall mean this Lease document including the Basic Lease
-----
Provisions and any and all Exhibits and Adgenda attached hereto now or in the
future.
1.11 "Letter of Credit" shall mean the Letter of Credit described in
----------------
Article 4 below.
1.12 "Permitted Use" shall mean the sole use for which Tenant may utilize
-------------
the Premises as specified in Item 11 of the Basic Lease Provisions and Article 8
below.
1.13 "Premises" shall have the meaning set forth in Item 6 of the Basic
--------
Lease Provisions.
1.14 "Rent" and "rent" shall mean Monthly Base Rent, Additional Rent and
----
all other charges payable hereunder and under any Exhibit or Adgenda to this
Lease, and any other monetary obligations of Tenant to Landlord under the
provisions of this Lease.
1.15 "Technology Party" shall mean any corporation, general or limited
----------------
partnership, joint venture, limited liability company or other person or entity
which is pursuing the application of Landlord's technology as a material part of
its business pursuant to a written agreement with Landlord.
1.16 "Tenant Affiliate" shall mean any corporation, general or limited
----------------
partnership, joint venture, limited liability company or other person or entity
(collectively, "person") which satisfies each of the following three criteria:
(i) such person controls, is controlled by or is under common control with
Tenant or results from a merger or consolidation with Tenant; (ii) Tenant
beneficially owns more than fifty percent (50%) of such person; and (iii) such
person has a net worth, determined in accordance with generally accepted
accounting principles ("GAAP"), in excess of Twenty Million Dollars
($20,000,000).
1.17 "Tenant Subsidiary" shall mean any corporation, general or limited
-----------------
partnership, joint venture, limited liability company or other person or entity
(collectively, "person") which satisfies each of the following two criteria: (i)
such person controls, is controlled by or is under common control with Tenant or
results from a merger or consolidation with Tenant; and (ii) Tenant beneficially
owns more than fifty percent (50%) of such person.
1.18 "Tenant Parties" shall mean Tenant, its employees, agents,
--------------
consultants, licensees, invitees, contractors, subcontractors, and any other
person for whom Tenant is legally responsible, provided that under no
circumstances shall any of Landlord Parties be deemed a Tenant Party for
purposed of this Lease.
1.19 "Term" shall mean the period of the Lease between the Commencement
----
Date and the Expiration Date (as such Commencement Date and Expiration Date are
defined in Section 2.1 below) or earlier termination of the Lease, but not to
exceed the period set forth in Item 7 of the Basic Lease Provisions unless
extended as provided in Section 2.3 below.
1.20 Other defined terms used in this Lease shall have the meanings set
forth in the Lease, including the following:
1.20.1 "Additional Rent" is defined in Article 44;
---------------
1.20.2 "Commencement Date" is defined in Section 2.1;
-----------------
1.20.3 "Expiration Date" is defined in Section 2.1; and
---------------
1.20.4 "Monthly Base Rent" is defined in Article 3.
-----------------
ARTICLE 2
TERM AND POSSESSION
-------------------
2.1 Commencement. The Term of this Lease shall be for approximately five
------------
(5) years and four (4) months as described in Item 7 of the Basic Lease
Provisions and shall commence on that date when Landlord delivers possession of
the Premises to Tenant in vacant, broom-clean condition, which Landlord
anticipates to occur on or about October 15, 1999 (the "Commencement Date"), and
shall expire on February 28, 2005 (the "Expiration Date"). Landlord shall
exercise commercially reasonable efforts (subject to Force Majeure delays) to
deliver the Premises to Tenant on or about October 15, 1999. Landlord shall
exercise commercially reasonable efforts to give Tenant at least thirty (30)
days prior written notice of each anticipated Commencement Date (but without any
liability on Landlord's part if Landlord shall fail to do so). Landlord and
Tenant shall execute a letter agreement confirming each exact Commencement Date
within five (5) business days following the Commencement Date. If the
Commencement Date and delivery of possession of the Premises to Tenant does not
occur on or before December 15, 1999, then Tenant's sole and exclusive remedy
with respect to such delay in the Commencement Date shall be to terminate this
Lease and the Xxxxxxx Lease by written notice given to Landlord on or before
December 31, 1999, and in the event of such termination both Landlord and Tenant
shall be released and relieved of their respective obligations and liabilities
under this Lease and under the Xxxxxxx Lease, Landlord shall return Tenant's
prepaid rent and the Letter of Credit paid or delivered by Tenant under this
Lease and under the Xxxxxxx Lease to Tenant and neither party shall have any
right to recover any losses, costs, expenses or damages (including, without
limitation, loss of profits, foreseeable or unforeseeable consequential damages
or special damages) from the other party.
2.2 Tenant's Acceptance of Possession. Tenant acknowledges and agrees that
---------------------------------
(i) Tenant has made all investigations which Tenant deems necessary concerning
(A) the condition of the Premises including the soil, air and groundwater
thereof, (B) Landlord's prior use of the Premises, (C) the adequacy of parking
for Tenant's intended office use of the Premises, (D) the compliance of the
Premises with all applicable statutes, laws, ordinances and regulations and (E)
Tenant's ability to operate its business in the Premises, (ii) Tenant shall
accept the Premises in "AS IS" and "WITH ALL FAULTS" condition on the
Commencement Date subject to all applicable zoning, municipal, county, state and
federal statutes, laws, ordinances and regulations governing and regulating the
use of the Premises and all easements, encumbrances, covenants, conditions and
restrictions of record, (iii) except as otherwise provided in this Lease,
Landlord has no obligation to alter or improve the Premises of any nature
whatsoever and (iv) Tenant acknowledges and agrees that neither Landlord nor any
of its agents or representatives has made any oral or written representations or
warranties of any nature whatsoever (a) with respect to the Premises including
the soil, air and groundwater thereof, (b) compliance or the Premises with
building codes and applicable laws, (c) the ability of Tenant to operate its
business in the Premises or (d) as to any of the matters set forth in subclauses
(i)(A) through (i)(E) above.
2.3 Option To Extend Term. Landlord shall notify Tenant in writing at
---------------------
least twelve (12) months prior to the Expiration Date of the initial Term of the
Lease and/or twelve (12) months prior to the expiration of the first Extended
Term (defined below), as applicable, as to whether Landlord will exercise its
right to repossess one or both of the buildings comprising the Premises (with
any such repossessed Premises being referred to herein as the "Repossessed
Premises") from and after the Expiration Date or the expiration of the first
Extended Term, as applicable (the "Recapture Right"). If Landlord, in Landlord's
sole and absolute discretion, exercises this Recapture Right, then (i) the Lease
shall terminate on the Expiration Date or the expiration of the first Extended
Term, as applicable, as to the Repossessed Premises, (ii) Tenant shall have no
right to extend this Lease for the Extended Term(s) (defined below) as to such
Repossessed Premises, (iii) from and after the Expiration Date or the expiration
of the first Extended Term, as applicable, Tenant shall have no further rights
or interests in the Repossessed Premises of any nature whatsoever, and (iv)
provided Landlord, a Landlord Affiliate and/or a Technology Party initially
occupies more than fifty percent (50%) of the Repossessed Premises for their own
use, Landlord shall be free to use the balance of the Repossessed Premises for
any purposes whatsoever, including, without limitation, assigning or subleasing
the balance of the Repossessed Premises to any person or entity for any purpose
whatsoever. If Landlord does not timely exercise its Recapture Right as to all
or any portion of the Premises upon the Expiration Date or the expiration of the
first Extended Term, as applicable, then Tenant shall have the option to extend
the term of this Lease solely as to that portion of the Premises (but not less
than an entire building) which is not Repossessed Premises for two (2) extended
term(s) of one (1) year each commencing upon the Expiration Date of the initial
Term of the Lease and the expiration of the first one-year Extended Term (each,
an "Extended Term"). Tenant may exercise the foregoing option to extend if and
only if (i) Tenant notifies Landlord in writing of its irrevocable election to
extend the Term of the Lease for the Extended Term no later than eleven (11)
months prior to the Expiration Date of the initial Term of the Lease or eleven
(11) months prior to the expiration date of the first one-year Extended Term, as
applicable, (ii) Tenant extends the term with respect to an entire building (and
not solely a portion of a building) and (iii) Tenant is not in material default
of the Lease (following the expiration of any applicable cure periods without
cure) either at the time of giving notice of its irrevocable election to extend
or on the commencement date of each Extended Term. If each of the conditions set
forth in the immediately preceding sentence are not satisfied in full, then
Tenant's option(s) to extend the term of the Lease shall lapse and be null and
void and the terms and provisions of the second sentence of this Section 2.3
shall apply as though Landlord had exercised its Recapture Right as to all of
the Premises. All of the terms and provisions of this Lease shall apply during
the Extended Term(s) except that (a) if Tenant extends the Lease as to less than
the entire Premises, Rent and the Face Amount of the Letter of Credit shall be
equitably reduced to reflect the reduction in square footage of the portion of
the Premises to be leased by Tenant during the Extended Term(s), (b) there shall
be no further right to extend the term of the Lease beyond the second Extended
Term, (c) except as expressly provided in this Lease, Landlord shall have no
obligation to make improvements to the Premises of any nature whatsoever, (d)
Tenant shall not be entitled to any abatement of Monthly Base Rent during either
Extended Term and (e) Monthly Base Rent during each the Extended Term shall be
determined and annually increased in accordance with the provisions of Exhibit B
---------
attached hereto. The foregoing right to extend the
-6-
term of the Lease is personal to Tenant and may not be assigned, sold, leased or
otherwise transferred, voluntarily or involuntarily, by or to any other person
or entity except to a Tenant Affiliate in accordance with Article 15 below.
2.4 HVAC Inspection. Prior to the Commencement Date, Landlord, at
---------------
Landlord's sole cost, shall cause a duly licensed heating, ventilating and air
conditioning ("HVAC") service and repair specialist to inspect the entire HVAC
system within the Premises, repair any deficiencies within such HVAC system and
certify in writing that the HVAC system is in good working order and repair.
2.5 Limited Early Access. Tenant, MCIWorldcom-Xxxxxx Fiber, and its
--------------------
subcontractors (collectively, "Early Access Parties") may enter upon the
Premises prior to the Commencement Date, at such times and places requested by
Tenant and approved by Landlord (such approval not to be unreasonably withheld
or delayed), for the sole purpose of allowing Tenant and/or any other Early
Access Party (a) to connect Tenant's telecommunications lines (including data,
voice and video cabling and wiring) to the exterior of the 0000 Xxxxxxxx
building and the 1550 Plymouth building, and (b) to install and test Tenant's
telecommunications equipment and systems (including data, voice and video
equipment and systems) within said buildings. In connection with each such entry
upon the Premises by an Early Access Party, each Early Access Party shall use
all reasonable efforts to ensure that the business of Landlord shall be
interfered with and inconvenienced as little as is reasonably practicable under
the circumstances and shall otherwise fully comply with Section 7.3 of the Lease
in all respects, which Section shall apply to each entry upon the Premises by an
Early Access Party pursuant hereto; provided, however, that an Early Access
Party shall only be required to give Landlord not less than ten (10) calendar
days prior notice for entries that contemplate work that is physically intrusive
(such as trenching and boring or drilling into the parking lot, ground, or walls
of the 1500 and 1550 Plymouth buildings) and not less than five (5) calendar
days prior notice for entries that contemplate work that is not physically
intrusive. Notwithstanding the foregoing, (i) Landlord may assign a security
guard to accompany each Early Access Party while on the Premises pursuant to
this Section 2.5 and (ii) any drilling by an Early Access Party into the hard
walls of the 1500 and 1550 Plymouth buildings shall, unless otherwise agreed to
by Landlord, take place after 5:00 p.m. California time on work days or at any
reasonable time on weekend days. Further, the provisions of Article 20 and
Sections 19.1, 19.2, 19.3.1, 19.3.2, 19.5, 19.6 and 19.7 of the Lease shall
apply and be in full force and effect during each entry upon the Premises by any
Early Access Party pursuant to this Section 2.5. Prior to and as a condition to
each such entry by an Early Access Party, Tenant shall furnish Landlord with
proof of the insurance required of Tenant under Sections 19.3.1, 19.3.2 and 19.6
of this Lease. Tenant agrees to defend, indemnify and save harmless Landlord its
officers, directors, employees, affiliates, subsidiaries, shareholders, lenders,
successors and assigns from all liabilities, costs, damages, fees, liens and
expenses suffered or incurred by them as a result of any activity, work or thing
done on or about the Premises by Tenant and/or any other Early Access Party
pursuant to this Section 2.5. Notwithstanding Tenant's rights under this Section
2.5, Tenant's obligation to pay Monthly Base Rent and Additional Rent shall not
commence until the Commencement Date.
-7-
ARTICLE 3
MONTHLY BASE RENT; NET LEASE
----------------------------
3.1 Monthly Base Rent. Tenant shall pay to Landlord as Monthly Base Rent
-----------------
for the Premises the sum(s) described in Item 8 of the Basic Lease Provisions
and as set forth on Exhibit B to this Lease during the entire Term and any
---------
Extended Term(s). The Monthly Base Rent shall be payable in advance on the first
day of each calendar month, without deduction, setoff, abatement, prior notice
or demand, commencing on the Commencement Date and continuing for each calendar
month thereafter during the Term of the Lease and the Extended Term(s), if
applicable. In the event the Term of this Lease commences or ends on a day other
than the first or last day of a calendar month, then the Monthly Base Rent for
such partial month shall be prorated in the proportion that the number of days
this Lease is in effect during such partial month bears to the number of days in
that calendar month, and such Monthly Base Rent shall be paid at the
commencement of such partial month. Monthly Base Rent shall be payable in lawful
money of the United States at the address of Landlord set forth in Item 5 of the
Basic Lease Provisions or at such other address as may be designated by Landlord
in writing pursuant to Article 23 below. Notwithstanding any other term of this
Lease to the contrary, a prepayment of Monthly Base Rent in the amount set forth
in Item 9 of the Basic Lease Provisions shall be made by Tenant upon execution
of this Lease and shall be applied to the Monthly Base Rent for the second (2nd)
full calendar month of the Term. Landlord hereby acknowledges receipt of such
prepaid rent from Tenant.
3.2 Forgiveness of Monthly Base Rent. As an inducement to Tenant to enter
--------------------------------
into this Lease, Tenant shall be entitled to unconditional forgiveness of
Monthly Base Rent in the amount of $228,000 for the first (lst) month of the
Term ("Forgiven Rent"). There shall be no abatement of Monthly Base Rent during
either Extended Term of this Lease. Tenant's obligation to pay in full all
Additional Rent and all other charges payable under this Lease shall not be
affected by the foregoing Forgiven Rent.
3.3 Additional Rent. In addition to the Monthly Base Rent reserved in
---------------
Section 3.1 above, Tenant shall reimburse to Landlord or pay to the parties
entitled thereto, as applicable, all impositions, Insurance Premiums (as defined
in Section 5.3 below), Property Taxes (as defined in Section 5.2 below),
operating charges, maintenance charges, construction costs, and any other
charges, costs and expenses which arise or may be contemplated under any
provisions of this Lease during the Term hereof and each Extended Term on the
terms set forth in this Lease. All of such charges, costs and expenses shall
constitute Additional Rent, and upon the failure of Tenant to timely reimburse
or pay any of such costs, charges or expenses, Landlord shall have the same
rights and remedies as otherwise provided in this Lease for the failure of
Tenant to pay rent. It is the intention of the parties hereto that this Lease
shall not be terminable for any reason by Tenant except for Landlord's uncured
material breach of this Lease as provided in Section 25.3 below and except as
otherwise expressly provided herein and that Tenant shall in no event be
entitled to any abatement of or reduction in Rent payable under this Lease
except as herein expressly provided. Any present or future law to the contrary
shall not alter this agreement of the parties.
-8-
ARTICLE 4
LETTER OF CREDIT
----------------
4.1 Letter of Credit as Security. Concurrent with the execution of this
----------------------------
Lease, Tenant shall deliver to Landlord the Letter of Credit (as defined in
Section 4.2 below) in the amount of One Million Eight Hundred Seventy-Five
Thousand Dollars ($1,875,000), which Letter of Credit shall secure the full and
faithful performance of each and every provision and condition of this Lease to
be performed by Tenant. The amount of the Letter of Credit shall be reduced to
Seven Hundred Fifty Thousand Dollars ($750,000) on February 1, 2002 if Tenant's
net worth on such date (determined in accordance with generally accepted
accounting principals ("GAAP")) exceeds Twenty Million Dollars ($20,000,000) and
(ii) the amount of the Letter of Credit shall be further reduced to Three
Hundred Seventy-Five Thousand Dollars ($375,000) on February 1, 2003 if Tenant's
net worth on such date (determined in accordance with GAAP) continues to exceed
Twenty Million Dollars ($20,000,000). There shall be no further reduction in the
stated amount of the Letter of Credit from and after February 1, 2003. The face
amount of the Letter of Credit (as reduced above from time to time upon
satisfaction of the foregoing conditions) is hereafter referred to as the "Face
Amount". Anything contained in this Article 4 to the contrary notwithstanding,
the Face Amount of the Letter of Credit shall not be reduced if Tenant has
previously committed an uncured default under this Lease. If an Event of Default
occurs under this Lease (including but not limited to an Event of Default with
respect to the obligation to pay Rent or to clean and restore the Premises upon
termination of the Lease), Landlord may, but shall not be required to, draw upon
the Letter of Credit for the payment of any Rent, interest, late charges or any
other sum in default, or for the payment of any other amount which Landlord may
spend or become obligated to spend by reason of the Event of Default or to
compensate Landlord for any other loss or damage which Landlord may suffer by
reason of the Event of Default, including, without limitation, costs and
reasonable attorneys' fees incurred by Landlord to collect on the Letter of
Credit and/or to recover possession of the Premises following an Event of
Default by Tenant hereunder. Tenant shall cause the Letter of Credit to remain
in effect during the entire Term of this Lease and for an additional period of
sixty (60) days following the expiration or earlier termination of this Lease.
If Tenant fails to maintain, renew or replace the Letter of Credit in its then
Face Amount at least thirty (30) days before its stated expiration date (or if
Tenant fails to maintain, renew or replace the letter of credit under Article 4
of the Xxxxxxx Lease in its then face amount at least thirty (30) days before
its stated expiration date), then Landlord may, without prejudice to any other
right or remedy, draw upon the entire amount of the Letter of Credit. Any amount
drawn by Landlord on the Letter of Credit pursuant to this Section 4.1 but not
applied by Landlord to satisfy Tenant's obligations hereunder shall be held by
Landlord as a security deposit. Landlord may commingle any proceeds from the
Letter of Credit with Landlord's general funds and Tenant shall not be entitled
to any interest thereon. If Landlord draws on any portion of the Letter of
Credit, Tenant shall, within three (3) business days after demand by Landlord,
either (a) deposit immediately available funds with Landlord in the amount that
when added to the remaining amount of the undrawn portion of the Letter of
Credit equals its then Face Amount or (b) deliver to Landlord written
documentation acceptable to Landlord executed by the Issuing Bank (as defined in
Section 4.2 below) confirming that the Issuing Bank has reinstated the Letter of
Credit to its then full Face Amount; and Tenant's failure to do either (a) or
(b) above shall constitute an Event of Default hereunder. If the funds received
by Landlord pursuant to a draw on the Letter of Credit exceed the amount applied
by Landlord to
-9-
cure the Event of Default, concurrently with and conditioned upon Tenant's
reinstatement of the Letter of Credit to its full Face Amount, Landlord shall
return any such excess funds to Tenant. If Tenant shall fully perform each and
every provision of this Lease required by Tenant to be performed, the Letter of
Credit (and any funds held by Landlord as a security deposit after drawing on
the Letter of Credit) shall be returned to Tenant (or, at Landlord's option, to
the last assignee of Tenant's interest hereunder) within sixty (60) days
following the later of the expiration of the Term or surrender of possession of
the Premises to Landlord. Notwithstanding the foregoing, the Letter of Credit
(and any funds held by Landlord as a security deposit after drawing on the
Letter of Credit) shall be immediately returned to Tenant upon the termination
of this Lease solely by reason of Landlord's material default hereunder. Tenant
shall not assign or encumber the Letter of Credit. Any attempt to do so shall be
void and Landlord shall not be bound by any such purported assignment or
encumbrance. In the event of bankruptcy or other insolvency proceedings filed by
or against Tenant, all sums drawn under the Letter of Credit shall be deemed to
be applied first to the payment of Rent and other charges due Landlord for all
periods prior to the effective date of such proceedings. If Landlord transfers
or assigns its interest in the Premises, Landlord may transfer or assign the
Letter of Credit to such transferee.
4.2 Form of Letter of Credit. Concurrent with the execution of this Lease,
------------------------
Tenant shall deliver to Landlord an irrevocable, unconditional standby letter of
credit in the original face amount of One Million Eight Hundred Seventy-Five
Thousand Dollars ($1,875,000) in the form attached hereto as Exhibit C (the
---------
"Letter of Credit") to secure the full and faithful performance of each and
every term and provision of this Lease to be performed by Tenant as set forth in
Section 4.1 above. The Letter of Credit shall be issued by a bank or financial
institution ("Issuing Bank") which is acceptable to Landlord and which accepts
deposits, maintains accounts, is FDIC insured and has a local Mountain View or
San Francisco office which will negotiate the Letter of Credit. The Letter of
Credit shall permit full or partial draws by Landlord or Landlord's assignee.
Tenant shall pay all expenses, points or fees incurred by Tenant in obtaining,
maintaining and renewing the Letter of Credit. As provided in Section 4.1 above,
Tenant shall cause the Letter of Credit to remain in full force and effect
during the entire term of this Lease and for a period of sixty (60) days
following the expiration or earlier termination of this Lease (except in the
case of termination of this Lease solely by reason of Landlord's material
default hereunder). Provided this Lease has not expired or terminated, Tenant
shall replace or renew the Letter of Credit from time to time at least thirty
(30) days before its stated expiration date. Failure to so replace or renew the
Letter of Credit shall constitute a default hereunder and Landlord shall
thereafter be entitled to draw the full amount of the Letter of Credit and hold
it as a cash security deposit. The terms of the Letter of Credit shall expressly
provide that the Letter of Credit is assignable by Landlord, as beneficiary
thereunder, to any transferee or assignee of Landlord's interest in the Premises
who expressly assumes in writing Landlord's obligations under this Lease.
ARTICLE 5
TENANT'S PAYMENT OF PROPERTY TAXES
AND INSURANCE PREMIUMS
----------------------
5.1 Payment of Property Taxes and Insurance Premiums. In addition to
------------------------------------------------
payment of Monthly Base Rent pursuant to Section 3.1 above, Tenant shall
reimburse on the terms set forth
-10-
in this Article 5 to Landlord, as part of Additional Rent hereunder, Property
Taxes (as defined in Section 5.2 below) and Insurance Premiums (as defined in
Section 5.3 below). Tenant shall reimburse Landlord for all Property Taxes paid
by Landlord for the Premises within ten (10) business days following Tenant's
receipt from Landlord of written demand for reimbursement of such Property Taxes
accompanied by a copy of the then applicable tax xxxx and a copy of Landlord's
check made payable to the taxing authority. Tenant shall likewise reimburse
Landlord for all Insurance Premiums paid by Landlord for the Premises within ten
(10) business days following Tenant's receipt from Landlord of written demand
for reimbursement of such Insurance Premiums accompanied by a copy of the
applicable insurance premium invoice and a copy of Landlord's check made payable
to the insurance carrier. If any Property Taxes or Insurance Premiums so paid by
Landlord cover any period of time prior to or after the expiration of the Term
hereof, Tenant's share of Property Taxes or Insurance Premiums shall be
equitably prorated to reflect only the period of time during which the Lease was
in effect.
5.2 Property Taxes Defined. The term "Property Taxes" as used herein shall
----------------------
mean and include (i) any and all real estate and personal property taxes and
other taxes, rates, charges, general and special assessments, transit charges,
housing fund assessments, liens, assessment bonds, district formation costs,
bonds, levies, fees and impositions whether general, special or supplemental,
unforeseen or foreseen, ordinary or extraordinary which are assessed, imposed,
charged, confirmed or levied with respect to the Premises, and/or any
improvements, fixtures and equipment and other property of Landlord, real or
personal, located thereon, but only to the extent each of the foregoing relates
to the period between the Commencement Date (as applicable) and the date this
Lease expires or sooner terminates and any costs, fees or expenses incurred in
contesting the amount or validity of any of the foregoing; (ii) any tax,
surcharge, levy, fee or assessment which may be imposed in addition to or in
lieu of real estate or personal property taxes against the Premises, but only to
the extent each of the foregoing relates to the period between the Commencement
Date (as applicable) and the date this Lease expires or sooner terminates; and
(iii) any service, use or other fee collected by governmental agencies in
addition to or in lieu of real estate or personal property taxes against the
Premises for services provided by such agencies, but only to the extent each of
the foregoing relates to the period between the Commencement Date (as
applicable) and the date this Lease expires or sooner terminates. The term
Property Taxes as used herein shall also include any new, replacement or
supplemental property taxes and any rental, excise, sales, mortgage, transaction
privilege, or other tax or levy, however denominated, imposed upon or measured
by the rental reserved hereunder or on Landlord's business of owning, operating
or leasing the Premises, but only to the extent each of the foregoing relates to
the period between the Commencement Date (as applicable) and the date this Lease
expires or sooner terminates. However, notwithstanding anything to the contrary
above or elsewhere in this Lease, the term "Property Taxes" shall not mean or
include (a) any income, franchise, capital stock, estate or inheritance taxes of
or applicable to Landlord or (b) any transfer taxes. Property Taxes shall also
include all increases in Property Taxes during the Term or Extended Term
including, without limitation, (a) annual increases, (b) increases due to a
reassessment of the Premises arising from a change in ownership or transfer of
all or part of Landlord's interest in the Lease, or the Premises or any
refinancing of the Premises or (c) any new construction, alterations or
renovations to the Premises. If any Property Taxes shall be payable in
installments over a period of time extending beyond the Term of the Lease (or
the Extended Term, if applicable), Tenant shall only be required to pay such
installments thereof as shall become due and payable during, or relate to
periods of time covered
-11-
by, the Term of the Lease (or any Extended Term, if applicable). Landlord shall
provide Tenant with a copy of its annual Property Tax statements.
5.3 Insurance Premiums. The term "Insurance Premiums" shall mean and
------------------
include all premiums paid or incurred by Landlord in obtaining and maintaining
the insurance coverages required to be maintained by Landlord under Section 19.4
below and other commercially reasonable insurance coverages which Landlord
acting as a prudent landowner and landlord may obtain and maintain, but only to
the extent such premiums paid for insurance coverage relate to the period
between the Commencement Date (as applicable) and the expiration or sooner
termination of this Lease.
ARTICLE 6
MAINTENANCE, REPAIR AND REPLACEMENT
-----------------------------------
6.1 Tenant's Obligations for the Premises. Except for the obligations of
-------------------------------------
Landlord under Article 13 (relating to the destruction of the Premises), Article
14 (relating to condemnation of the Premises) and Sections 6.3 and 9.2 hereof,
and except for damage caused by Landlord or the Landlord Parties (which shall be
the sole and exclusive responsibility and cost of Landlord), Tenant, at Tenant's
sole cost and expense, shall keep in good and neat order, condition and repair
the Premises and every part thereof, structural and non-structural, whether or
not capital in nature (and whether or not the portion of the Premises requiring
repair or replacement, or the means of repairing or replacing the same are
reasonably accessible to Tenant, and whether or not the need for repairs,
replacements and/or capital improvements occurs as a result of Tenant's use, any
prior use, the elements or age of such portion of the Premises, or alterations,
additions, repairs or replacements required by governmental authority, whether
or not related to Tenant's specific use of the Premises) including, without
limitation, repair and replacement (including any and all replacements and
capital improvements) of all plumbing, electrical, heating, ventilating and air
conditioning systems, all elevators, stairways and stairwells, all sprinkler and
life safety systems, wiring and equipment within the Premises, all fixtures,
interior and exterior non-bearing walls, ceilings, floors, windows, doors, plate
glass, and all landscaping, landscaping and irrigation systems, driveways,
parking lots, loading docks, fences and signs located on the Premises and all
sidewalks and pathways located on the Premises; provided, however, that the cost
of any capital improvements or replacements having a useful life (as determined
in accordance with GAAP) longer than the Lease Term (including the Extended
Term(s), if any), shall be amortized over such useful life and Tenant shall only
be obligated to pay, each month during the remainder of the Term (and Extended
Term(s), if any), on the date on which Base Monthly Rent is due, an amount equal
to the product obtained by multiplying the cost of such capital improvement or
replacement by a fraction, the numerator of which is one, and the denominator of
which is the number of months of the useful life of such capital improvement or
replacement (as such useful life is determined in accordance with GAAP), with
Tenant reserving the right to prepay its obligation at any time. Within ten (10)
business days after written demand from Tenant, Landlord shall reimburse Tenant
in full for the cost of any capital improvements or replacements made to the
Premises by Tenant pursuant to this Section 6.1. Tenant, at Tenant's sole
expense, shall procure and maintain during the Term a maintenance contract with
a contractor specializing in and experienced in maintenance and service of the
heating, ventilating and air conditioning systems for the Premises, which
-12-
maintenance contract and contractor shall be reasonably acceptable to Landlord.
Prior to the Commencement Date, Landlord shall exercise reasonable efforts to
have its landscaping and janitorial vendors enter into service agreements with
Tenant to provide services to Tenant which are comparable to the services which
they previously provided to Landlord at the Premises at rates comparable to
those which they charge Landlord.
6.2 Landlord's Rights. If an Event of Default involving Tenant's failure
-----------------
to perform Tenant's obligations under Section 6.1 above or under any other
Section of this Lease should occur, Landlord may at its option (but shall not be
required to) enter upon the Premises upon ten (10) business days prior written
notice to Tenant (except in an emergency, in which case no notice shall be
required) to cure such Event of Default on Tenant's behalf, and all reasonable
costs thereof together with interest thereon as set forth in Section 34.1 below
shall constitute Additional Rent hereunder and shall be due and payable within
five (5) business days after written demand by Landlord. Notwithstanding the
foregoing, in the case of an emergency resulting from Tenant's failure to
perform its obligations under Section 6.1 above or under any other Section of
this Lease, Landlord may act immediately pursuant to this Section 6.2
6.3 Landlord's Obligations for the Premises. Except for the obligations of
---------------------------------------
Landlord under this Section 6.3, Section 9.2, Article 13 and Article 14 below,
and except for damage caused by Tenant or the Tenant Parties (which shall be the
sole and exclusive responsibility and cost of Tenant), Tenant acknowledges and
agrees that Landlord shall have no obligation, in any manner whatsoever, to
repair or maintain the Premises, whether structural or nonstructural. Landlord
shall, at its sole cost and expense keep in good and neat order, condition and
repair, the roof and roof membrane at the Premises, the skylights at the
Premises, the foundation for the Premises, and the structural walls (including,
without limitation, interior and exterior bearing walls) at the Premises,
whether or not capital in nature, including, without limitation, repair and
replacement (including any and all replacements and capital improvements) of the
foregoing items.
6.4 Waivers. Except as expressly provided in Articles 13 and 14 below,
-------
there shall be no abatement of Rent and no liability of Landlord by reason of
any injury to or interference with Tenant's business arising from Tenant's
making repairs pursuant to Sections 6.1 above or Landlord making repairs
pursuant to Section 6.2 above (where Tenant has failed to make such repairs) and
Section 6.3 above. Tenant expressly waives the benefit of any statute, law or
regulation now or hereafter in effect, including, without limitation, California
Civil Code Sections 1941 and 1942, which would otherwise afford Tenant the right
to make repairs at Landlord's expense or terminate the Lease.
ARTICLE 7
IMPROVEMENTS AND ALTERATIONS; LIENS
-----------------------------------
7.1 Original Tenant Improvements. On the Commencement Date Landlord shall
----------------------------
deliver possession of the Premises to Tenant in "AS IS" and "WITH ALL FAULTS"
condition. Tenant, at Tenant's sole cost and expense, shall construct and
install all of the Tenant Improvements (as defined in the Work Letter for Tenant
Improvements attached to this Lease as Exhibit D and incorporated herein by this
----------
reference (the "Work Letter")) within the Premises in a
-13-
first-class, diligent and workmanlike manner and fully and timely comply with
each and every term, covenant and condition set forth in the Work Letter. Tenant
shall exercise its best efforts to install within the Premises Tenant
Improvements which will have a remaining useful life to Landlord at the
expiration or earlier termination of the Lease.
7.2 Furniture and Telephone/Network Equipment. During the Term and any
-----------------------------------------
Extended Term(s) of the Lease, Landlord shall permit Tenant to use all of
Landlord's existing cubicles, office furniture and lobby/conference room
furniture (but excluding all ergonomic furniture and all exam room furniture in
Landlord's health clinic) listed on Schedule 1 attached to this Lease in its
----------
"AS-IS" and "WITH ALL FAULTS" condition (collectively, the "Remaining
Furniture") (but expressly excluding from the Remaining Furniture Landlord's
office equipment, fixtures and trade fixtures, which Landlord shall remove from
the Premises prior to the Commencement Date). Tenant shall be permitted to use
the Remaining Furniture at no additional rental. Prior to the Commencement Date,
Landlord and Tenant shall jointly make a detailed inspection and written
inventory of the Remaining Furniture to ensure that Schedule 1 both (i) properly
----------
describes all of the Remaining Furniture and (ii) properly describes the
physical condition of the Remaining Furniture as of the Commencement Date.
Tenant, at Tenant's sole cost and expense, shall maintain the Remaining
Furniture in as good condition and repair as when received and at the expiration
or earlier termination of the Term of the Lease, Tenant shall return the
Remaining Furniture to Landlord in as good a condition as received, ordinary
wear and tear and damage by fire, other casualty or acts of God excepted. The
Remaining Furniture shall at all times during the Term and any Extended Term(s)
be and remain the sole and exclusive property of Landlord; provided, however,
that Tenant, at Tenant's sole cost and expense, shall be obligated to insure the
Remaining Furniture under its "All-Risk" property insurance policy described in
Section 19.3 below. Any and all insurance proceeds relating to the Remaining
Furniture shall be the sole and exclusive property of Landlord. Landlord and
Tenant hereby agree that the value of the Remaining Furniture for insurance
purposes only is Two Million One Hundred Fifty Six Thousand Nine Hundred Five
DOLLARS ($2,156,905,00). Tenant agrees that the Remaining Furniture shall remain
--------------
within the Premises and that in no event shall the Remaining Furniture be
removed from the Premises. In addition, on the Commencement Date Landlord shall
leave in place within the Premises Landlord's telephone lines and cable/network
lines; provided, however, that Tenant acknowledges and agrees that (a) on or
before the Commencement Date Landlord shall disconnect all such telephone lines
and cable/network lines from Landlord's central telephone/data network switch
room located in the Xxxxxxx Premises and (b) Tenant, at Tenant's sole cost and
expense, and as part of Tenant's installation of its Tenant Improvements under
the Work Letter, shall install its own dedicated central telephone/data network
switch room and connect its telephone and data network cabling lines to its
central telephone/data network switch room.
7.3 Alterations by Tenant. Other than the initial Tenant Improvements,
---------------------
Tenant shall make no alterations, additions or improvements to the Premises
without the prior written consent of Landlord, which consent shall not be
unreasonably withheld or delayed. Landlord may impose, as a condition of such
consent, such reasonable requirements as Landlord may deem desirable including,
without limitation, the requirement that Tenant remove such alterations,
additions or improvements upon the expiration or earlier termination of the
Lease. Landlord shall advise Tenant in writing at the time Tenant makes its
initial Tenant Improvements under the Work Letter (as to the initial Tenant
Improvements) and at the time Tenant requests
-14-
Landlord's consent to any subsequent alterations whether Landlord will require
Tenant to remove such alterations from the Premises upon the expiration or
earlier termination of this Lease. Notwithstanding the requirements in this
Section 7.3, nonstructural alterations, additions or improvements which do not
affect building systems or the exterior of the Premises and that cost less than
Fifty Thousand Dollars ($50,000) in the aggregate in any calendar year shall not
require Landlord's prior written consent, but Landlord shall be entitled to at
least ten (10) days prior written notice thereof before Tenant commences such
alterations, additions or improvements. Tenant shall submit all plans and
specifications relating to any proposed alterations, additions or improvements
which exceed Fifty Thousand Dollars ($50,000) in the aggregate in any calendar
year to Landlord for Landlord's prior written approval. No materials used in
Tenant's alterations shall be subject to any security interest or lien and no
part of the Premises shall be subject to any mechanics' or materialmen's lien by
reason of Tenant's alterations. No such alterations shall affect the exterior
appearance of the Premises and it shall be deemed reasonable for Landlord to
refuse to consent to any such alterations. All work approved by Landlord shall
be performed by Tenant or Tenant's contractors in a first-class, diligent and
workmanlike manner and so as not to unreasonably interfere with any owners,
tenants or occupants of adjoining premises or buildings. Tenant shall utilize
for such purposes only licensed contractors and materials reasonably approved in
writing by Landlord (and Landlord hereby approves Xxxxx Xxxxx). Any construction
by Tenant shall be in conformance with the plans and specifications reasonably
approved by Landlord and with any and all applicable rules and regulations of
any federal, state, county or municipal agency or other governmental body having
jurisdiction over the Premises (including, without limitation, the Americans
With Disabilities Act and its state and local counterparts) and with any
applicable codes and ordinances regardless of whether such rules, regulations,
codes or ordinances relate to structural, permanent or non-structural
alterations. All alterations of Tenant shall be done at Tenant's sole cost and
expense. Tenant agrees to give Landlord written notice of the commencement date
of any such approved alterations, improvements, additions or repairs to be made
within the Premises at least ten (10) days prior to the commencement of any such
work in order to give Landlord time to post notices of nonresponsibility. Tenant
further agrees to reimburse Landlord all of Landlord's reasonable costs incurred
for review of any plans and specifications submitted by Tenant for its
alterations (other than the initial Tenant Improvements) and in reviewing the
progress of such alterations, but not to exceed Two-Thousand five Hundred
Dollars ($2,500) for each set of alterations.
7.4 Liens. Tenant shall keep the Premises free from any liens arising out
-----
of any work performed, materials furnished or obligations incurred by or for
Tenant. If Tenant fails to keep the Premises free from any such liens and does
not, within twenty (20) days following the imposition of any such lien, cause
the same to be released of record by payment or posting of a proper bond,
Landlord shall have, in addition to all other remedies provided herein and by
law, the right, but not the obligation, to cause such lien to be released by
such means as Landlord shall deem proper, including payment of or defense
against the claim giving rise to such lien. All sums paid by Landlord and all
expenses incurred by it in connection therewith (including attorneys' fees and
costs) shall automatically create an obligation of Tenant to pay an equivalent
amount as Additional Rent, which shall be payable by Tenant on Landlord's demand
with interest as set forth in Section 34.1 below. Such interest charged shall
not constitute Landlord's exclusive remedy nor compromise or limit any other
rights granted Landlord by this Lease or by law or equity. Nothing herein shall
imply any consent by Landlord to subject Landlord's estate
-15-
to liability under any mechanic's lien law. Tenant may contest the validity
and/or amount of any lien imposed on the Premises, provided that Tenant has
caused such lien to be released of record by the payment or posting of the
proper bond.
ARTICLE 8
USE OF PREMISES
---------------
8.1 Tenant's Use. Tenant shall use and occupy the Premises solely for
------------
development, marketing and sale of its Chemdex electronic commerce solutions,
general office purposes, purposes related or incidental thereto, and for no
other use or purpose whatsoever without the prior written consent of Landlord,
which consent may be withheld or conditioned in Landlord's sole discretion.
Tenant covenants and agrees that its electronic commerce solutions business does
not and shall not require Tenant to use or bring onto the Premises, other than
Permitted Materials, any Hazardous Materials, pharmaceuticals, drugs, chemicals
or other materials which are the subject of its electronics commerce solutions
business or otherwise and that Tenant shall not use or bring onto the Premises,
other than Permitted Materials, any Hazardous Materials, pharmaceuticals, drugs,
chemicals or other similar materials (even in di minimus amounts) for any reason
or purpose whatsoever. Tenant shall not use or occupy the Premises in violation
of any law, regulation, code, ordinance or governmental approval or condition
for the Premises, and shall, upon written notice from Landlord, discontinue any
use of the Premises which is not permitted by this Lease. Tenant shall, at
Tenant's sole cost and expense, comply with any directive of any governmental
authority which shall, by reason of the specific nature of Tenant's use or
occupancy of the Premises, impose any duty, condition, order, exaction or other
demand upon Tenant or Landlord with respect to the Premises including, without
limitation, any Environmental Laws, or with respect to the use or occupation
thereof. Tenant shall secure any and all permits and licenses required to
conduct its business in the Premises. Tenant shall not do (or permit any Tenant
Party to do) anything which will invalidate or increase the cost of any
insurance policy covering the Premises and/or property located therein.
8.2 Nuisance or Waste. Tenant shall not maintain, commit (or permit any
-----------------
Tenant Party to commit) any nuisance or waste in, on or about the Premises, or
obstruct or interfere in any way with the rights of other tenants or occupants
of the Premises, or injure or annoy them by permitting or making any disturbing
or excessive noise, or by permitting objectionable odors to emanate from the
Premises, or use or allow the Premises to be used by any Tenant Party for any
unlawful purpose. Tenant shall not without Landlord's prior written consent,
place a load upon any floor that exceeds the load per square foot that such
floor is designed to carry or that is then allowed by law.
8.3 Tenant Sign. Tenant, at Tenant's sole cost and expense, and provided
-----------
Tenant complies with all applicable laws, statutes, ordinances, codes, rules,
regulations, orders and other lawful requirements of governmental agencies,
shall have the right to install no more than two (2) monument signs at the
Premises. The location(s), type, size, color, content, materials and
illumination of any of Tenant's monument signs shall be subject to Landlord's
prior written approval, which approval shall not be unreasonably withheld or
delayed. Upon the expiration or earlier termination of this Lease, Tenant shall
remove all signs and repair and restore any damage to the Premises caused by
such removal.
-16-
8.4 Parking. At all times during the Term and any Extended Terms, Tenant
-------
shall be permitted to use, on an exclusive basis, all of the parking presently
serving the Premises. Tenant shall satisfy itself in all respects as to the
location and sufficiency of the above-described parking for its intended
purposes and use of the Premises prior to the Commencement Date; provided,
however, that Landlord represents that there are approximately four (4) parking
spaces per 1,000 rentable square feet of the Premises.
ARTICLE 9
HAZARDOUS MATERIALS
-------------------
9.1 Environmental Disclosures; As-Is. Landlord hereby discloses to Tenant
--------------------------------
and Tenant hereby acknowledges that Landlord has advised Tenant that groundwater
in and around the Premises may be contaminated with Hazardous Materials which
were released by parties other than Landlord, including, without limitation,
significant quantities of halogenated volatile organic compounds released into
the groundwater by Teledyne Semiconductor and Spectra-Physics Laser, both of
whom operated facilities located directly upgradient of the Premises. Landlord
has provided Tenant with the groundwater monitoring reports described on
Schedule 2 attached hereto, which Tenant acknowledges receipt of and, except for
-----------
disclosures to the attorneys, auditors, officers, directors, shareholders,
accountants, investment bankers, lenders, and consultants of Tenant or
disclosures required by law, agrees to keep confidential and not to disclose the
contents thereof (to the extent not a matter of public record) during or
subsequent to the term of this Lease without the prior written consent of
Landlord which Landlord may grant or withhold in its sole discretion. Tenant may
obtain more information about the groundwater in and around the Premises from
publicly available files at the Regional Water Quality Control Board and other
agencies. By entering into this Lease, Tenant acknowledges and agrees (a) that
Tenant has had an opportunity to hire any consultants and make any inquiries
about the environmental condition of the Premises and the soil and groundwater
conditions in and around the Premises that Tenant deems desirable, (b) that
Tenant's representatives and advisors are knowledgeable in real estate and
environmental matters, (c) that Tenant accepts the Premises in "AS-IS" and "WITH
ALL FAULTS" condition and (d) that Tenant is not relying on any warranty or
representation, express or implied, by or on behalf of Landlord with respect to
the Premises including the soil, air and groundwater thereof. Landlord makes no
representations and warranties concerning (x) the environmental condition of the
Premises or the environment in and around the Premises including the soil, air
and groundwater thereof, (y) the presence or absence of Hazardous Materials in
the Premises and the soil, air and groundwater thereof, or (z) the safety of the
Premises for Tenant's employees or the likelihood that by demolition of portions
of the Premises and improving the Premises pursuant to the Work Letter and
occupying and using the Premises, Tenant's employees will be exposed to
Hazardous Materials.
9.2 Landlord's Indemnity. Except with respect to (i) any soil or
--------------------
groundwater contamination in and around the Premises existing as of the
Commencement Date and any subsurface mitigation of Hazardous Materials from
other property from and after the Commencement Date and (ii) those matters which
are covered by Tenant's express indemnification and defense obligations set
forth in Section 9.5 below, Landlord shall indemnify, defend and hold Tenant and
its officers, directors, employees, affiliates, subsidiaries, shareholders,
lenders, successors and assigns harmless from and against all claims, damages,
-17-
liabilities, losses, fines, penalties, consequential damages, costs and
expenses, demands, causes of action, judgments and attorneys' and consultants'
fees, whether foreseeable or unforeseeable, directly or indirectly, to the
extent arising out of Landlord's failure to remove any Hazardous Materials
(other than Hazardous Materials contained within building materials located in
the 1500 and 1550 Plymouth buildings) to the levels required by applicable
Environmental Laws and government agencies having jurisdiction therefor from
within any of the buildings comprising the Premises on or before the
Commencement Date, which indemnity shall include, without limitation, the cost
of any required or necessary repair, cleanup or detoxification of the Premises
and the preparation of any closure or other required plans. Neither the
acknowledgements or agreements of Tenant in Section 9.1 nor the strict
compliance by Landlord with all laws pertaining to Hazardous Materials shall
excuse Landlord from Landlord's obligations of indemnification pursuant to this
Section 9.2. Landlord's obligations pursuant to the foregoing indemnity shall
survive the expiration or earlier termination of this Lease. If any action or
proceeding is brought against Landlord based on the foregoing Landlord, upon
notice from Tenant, shall immediately defend Tenant at Landlord's expense with
counsel reasonably acceptable to Tenant.
9.3 Compliance with Environmental Laws. Tenant shall, at Tenant's sole
----------------------------------
cost and expense, comply with all Environmental Laws applicable to its
operations within the Premises and will at its sole expense obtain, procure and
comply with all permits, licenses and other governmental approvals required for
Tenant's use of the Premises. Tenant shall not permit any Tenant Party to use,
manufacture, handle, treat, transport, produce, dispose of, discharge,
distribute, release, sell, or store any Hazardous Materials (other than
Permitted Materials) in, on or around the Premises during the Term of this
Lease. Notwithstanding the foregoing, Tenant and other Tenant Parties may use,
in compliance with all applicable laws, including Environmental Laws, reasonable
amounts of typical office and janitorial supplies and products typically used in
offices and which are sold over the counter to the public at retail and, during
the construction of the Tenant Improvements or any alterations approved by
Landlord, ordinary and necessary building materials and containerized petroleum
products stored and used in compliance with all laws (collectively, "Permitted
Materials").
9.4 Investigation and Remediation of Hazardous Materials. Tenant shall
----------------------------------------------------
promptly give Landlord copies of any notices, inquiries, claims or documents
received by Tenant from governmental agencies or third parties concerning the
presence of Hazardous Materials in, under and around the Premises, including the
air, soil and groundwater thereof. If, during the Term of this Lease, Tenant, or
Tenant Parties spill, release, discharge, dispose of or introduce Hazardous
Materials to the Premises or if any Hazardous Materials used by Tenant are found
in the soil, atmosphere, surface water or groundwater on, under or about the
Premises due to Tenant's, or Tenant Parties' acts or negligence, Tenant, at
Landlord's option, shall promptly take all actions at its sole cost and expense,
including without limitation, investigation, testing, removal actions,
reporting, cleanup, remediation, and monitoring necessary to return the Premises
and any other affected properties to the condition required by applicable
Environmental Laws, all in accordance with Environmental Laws and the
requirements of all governmental agencies, provided that Landlord's written
approval of such actions shall first be obtained (a "Tenant Cleanup"). Landlord
shall not unreasonably withhold or delay such approval. Tenant shall promptly
provide Landlord with the results of any test, investigation or inquiry
conducted by or on behalf of Tenant in connection with the presence or suspected
presence of Hazardous Material
-18-
contamination on, under or about the Premises, provided Landlord agrees to keep
the same confidential on the same terms as Tenant pursuant to Section 9.1. With
respect to any Tenant Cleanup, Landlord may, at its election and after
consultation with Tenant concerning remediation costs, control the investigation
and clean-up of the contamination and discussions and negotiations with all
governmental authorities, which shall nevertheless be at Tenant's sole cost and
expense.
9.5 Tenant Indemnity. Except with respect to (A) any soil or groundwater
----------------
contamination in and around the Premises existing as of the Commencement Date
and any subsurface migration of Hazardous Materials from other property that
contaminates the soil and groundwater in and around the Premises from and after
the Commencement Date and (B) those matters which are covered by Landlord's
express indemnification and defense obligations set forth in Section 9.2 above,
Tenant shall indemnify, defend and hold Landlord and its officers, directors,
employees, affiliates, subsidiaries, shareholders, lenders, successors and
assigns harmless from and against all claims, damages, liabilities, losses,
fines, penalties, consequential damages (including diminution of value of the
Premises and lost rent), costs and expenses, demands, causes of action,
judgments and attorneys' and consultant's fees, whether foreseeable or
unforeseeable, directly or indirectly arising out of (i) the release or
discharge during the Term or any Extended Term hereof of any Hazardous Materials
contained in the building materials located in the 1500 or 0000 Xxxxxxxx
buildings provided such release or discharge is the result of Tenant's
construction of its initial Tenant Improvements within the Premises and any
subsequent alterations, additions or improvements made by or for Tenant (which
claims include, but are not limited to, employee exposure and toxic tort claims)
and (ii) Tenant's and Tenant Parties' use, handling, generation, storage,
disposal, exposure of others to, emission or release of Hazardous Materials on
or about the Premises during the Term or any Extended Term or a breach of
Tenant's obligations under this Article 9. The foregoing indemnity obligations
shall include, without limitation, the cost of any required or necessary repair,
cleanup or detoxification of the Premises or other properties and the
preparation of any closure or other required plans, whether such action is
required or necessary prior to or following the termination of this Lease.
Neither the written consent by Landlord to the use, generation, storage or
disposal of Hazardous Materials nor the strict compliance by Tenant with all
laws pertaining to Hazardous Materials shall excuse Tenant from Tenant's
obligations of indemnification pursuant to this Section 9.5. Tenant's
obligations pursuant to the foregoing indemnity shall survive the expiration or
earlier termination of this Lease. If any action or proceeding is brought
against Landlord based on the foregoing, Tenant, upon notice from Landlord,
shall immediately defend Landlord at Tenant's expense with counsel reasonably
acceptable to Landlord. Except for Landlord's covenants, agreements and
obligations expressly set forth in this Lease, Tenant hereby waives, releases
and relinquishes any and all rights, claims and causes of action which Tenant
may have or may be entitled to assert against Landlord, whether known or unknown
(a) with respect to the environmental condition of the Premises and the soil,
air and groundwater thereof, including, without limitation, any and all rights,
claims and causes of action arising under or with respect to the California
Health and Safety Code, Title 42 of the United States Code Section 9601 et.
--
seq., the federal and state Occupational Health & Safety Acts, and common law
------
tort theories and/or (b) arising out of the use, generation, handling, exposure
of others to, disposal or release of Hazardous Materials by Tenant and Tenant
Parties on, in, or about the Premises or a breach of Tenant's obligations under
this Section 9.5. With respect to the foregoing waivers only, Tenant
-19-
expressly waives the benefits of Civil Code Section 1542 and any similar statute
or common law that would render a waiver of unknown claims unenforceable.
9.6 Rent Abatement for Hazardous Material Condition. Until such time as
-----------------------------------------------
any Hazardous Material Condition (not created by Tenant or any Tenant Party),
should it occur, has been remediated in accordance with Environmental Laws such
that the Premises can be safely used and occupied by Tenant for the conduct of
its normal operations at the Premises, the Rent hereunder shall be abated in
proportion to the part of the Premises which is unusable by Tenant for the
conduct of its normal operations at the Premises by reason of such Hazardous
Material Condition.
9.7 Non-Responsibility of Tenant. Notwithstanding anything to the contrary
----------------------------
in Sections 9.1 through 9.6 above or elsewhere in this Lease, except to the
extent set forth in Tenant's indemnity in Section 9.5 above, no provision of
this Lease shall obligate Tenant to investigate, monitor, remove, remediate, or
otherwise respond to, or to indemnify, defend or hold harmless Landlord or any
other person as a result of or in connection with, any Hazardous Materials that
(A) were present in any state or form in, on, under or about the Premises on the
Commencement Date or at any time prior thereto, or (B) which may migrate onto or
under the Premises at any time after the Commencement Date, or (C) which are
otherwise not used, handled, stored, generated, produced, manufactured, disposed
of or introduced in, upon or about the Premises by Tenant or a Tenant Party.
9.8 Survival. The provisions of this Article 9 shall survive the
--------
expiration or earlier termination of the Lease for any reason.
ARTICLE 10
UTILITIES AND SERVICES
----------------------
10.1 Utilities and Services for the Premises. Tenant, at Tenant's sole
---------------------------------------
cost and expense, shall cause to be provided to the Premises and shall pay
directly for all water, sewer, gas, electric power, heating, ventilating and air
conditioning ("HVAC") and other utilities and services supplied to the Premises
together with any taxes thereon. Tenant shall provide and pay for its own
janitorial services for the Premises and for any security services or systems
desired by Tenant. The janitorial services which Tenant provides to the Premises
shall be comparable to those provided by Landlord in the 1010 Xxxxxxx building.
10.2 No Security Services. Landlord shall not provide any security
--------------------
services for the Premises, such security services, if desired by Tenant, being
the sole and exclusive responsibility and cost of Tenant. Tenant hereby waives
any and all claims by reason of Landlord not providing such security services.
10.3 Interruptions. Notwithstanding the provisions of this Article 10,
-------------
Landlord shall not be liable for, and Tenant shall not be entitled to, except as
provided below, any abatement or reduction of Rent or other damages, remedies or
relief of any nature whatsoever by reason of the unavailability of any of the
foregoing utilities or services for the Premises regardless of whether such
failure is caused by accident, breakage, repairs, strikes, lockouts or other
labor disturbance
-20-
or disputes of any character, governmental regulation or moratorium or other
governmental action; provided, however, that if the interruption in utilities or
services is caused by the negligence or willful misconduct of Landlord or any
Landlord Party and such interruption unreasonably interferes with the conduct of
Tenant's business in the Premises, then Tenant shall be entitled to equitable
rent abatement to the extent the Premises are unusable by Tenant in the conduct
of its normal business therein commencing on the second (2/nd/) business day of
such interruption and continuing until such interruption is sufficiently
remedied to permit Tenant to recommence its business operations in the Premises.
Any such failure, stoppage or interruption of any such utilities or services
shall not be construed either as an eviction of Tenant, or relieve Tenant from
the obligation to perform any term, covenant or agreement of this Lease.
Landlord and Tenant shall act jointly and in good faith and exercise their best
efforts to have utility service repaired or restored immediately or as promptly
as possible under the circumstances.
ARTICLE 11
RULES AND REGULATIONS
---------------------
Tenant agrees to abide by and to cause all Tenant Parties to abide by
all reasonable and nondiscriminatory Rules and Regulations for the Premises
imposed by Landlord. Such Rules and Regulations are imposed for the cleanliness,
good appearance, proper maintenance, good order and reasonable use of the
Premises.
ARTICLE 12
TAXES ON TENANT'S PROPERTY
--------------------------
12.1 Tenant's Property. Tenant shall be solely liable for and shall pay
-----------------
prior to delinquency, any and all taxes, levies and assessments imposed upon any
personal property, improvements, equipment, furnishings or trade fixtures placed
by Tenant in or about the Premises (including, without limitation, the Remaining
Furniture), as well as all taxes, levies and assessments imposed on Tenant's
initial Tenant Improvements and on any subsequent alterations, additions or
improvements installed by or on behalf of Tenant within or to the Premises.
Wherever possible, Tenant shall cause all of its personal property,
improvements, equipment, furnishings and trade fixtures and all of its
alterations, improvements and additions to the Premises including, without
limitation, Tenant's initial Tenant Improvements, to be assessed and billed
separately from the real property tax xxxx for the Premises. If any such taxes,
levies and assessments are levied against Landlord or Landlord's property or if
the assessed value of the Premises is increased by the inclusion therein of a
value placed upon such personal property, improvements, equipment, furnishings
or trade fixtures of Tenant or upon Tenant's alterations, improvements or
additions to the Premises, including Tenant's initial Tenant Improvements,
Tenant shall upon demand pay as Additional Rent all such taxes, levies and
assessments so levied against Landlord.
12.2 License Fees and Business Taxes. Tenant shall pay, prior to
-------------------------------
delinquency, all license fees and taxes which may be imposed upon the business
of Tenant conducted on the Premises. Landlord shall not be responsible for the
payment of any such license fees or taxes.
-21-
ARTICLE 13
FIRE OR CASUALTY; ABATEMENT
---------------------------
13.1 Restoration. If, at any time prior to the last twelve (12) months of
-----------
the Term, the Premises or any part thereof is damaged or destroyed by fire or
other casualty required to be covered by the "All Risk" Insurance described in
Section 19.4.1 below, the damage and destruction thereto shall be repaired and
the Premises restored by and at the expense of Landlord, but only up to the
amount of available insurance proceeds under the "All Risk" Insurance described
in Section 19.4.1 below (unless no proceeds are available because Landlord
failed to maintain such "All-Risk" Insurance in accordance with this Lease)
provided such repairs can, in Landlord's reasonable opinion, be made within two
hundred seventy (270) days after the occurrence of such damage or destruction
without the payment of overtime or other premiums, and the Lease shall continue
in full force and effect. If such damage or destruction occurs during the last
twelve (12) months of the Term, or is caused by a casualty not required to be
covered by such "All Risk" Insurance, or if, in Landlord's reasonable opinion,
such repairs and restoration cannot be so made within two hundred seventy (270)
days after the occurrence of such damage or destruction, the Lease may be
terminated by Landlord as provided in Section 13.3 below. Additionally, if such
damage or destruction occurs during the last twelve (12) months of the Term or
if, in Landlord's reasonable opinion, such repairs cannot be made within two
hundred seventy (270) days after the occurrence of such damage or destruction,
then the Lease may be terminated by Tenant as provided in Section 13.3 below.
13.2 Rent Abatement. Until Landlord's required repairs and restoration
--------------
pursuant to Section 13.1 above are completed, the Rent hereunder shall be abated
in proportion to the part of the Premises which is unusable by Tenant for the
conduct of its normal business or operations at the Premises. If the damage or
destruction is due to the negligence or willful misconduct of Tenant or Tenant's
employees, agents, contractors, subcontractors, invitees or licensees, there
shall be no abatement of Rent regardless of the period during which the Premises
is unusable. If this Lease is not terminated by Landlord or Tenant as provided
in Section 13.3 below, Tenant shall be responsible for making all repairs to
and/or replacement or restoration of its initial Tenant Improvements and its
additions, improvements, alterations and trade fixtures made by or for Tenant to
the Premises and all of its furniture, fixtures, equipment and personal
property, including, without limitation, the Remaining Furniture.
13.3 Special Elections. If repairs for damage and destruction covered by
-----------------
Section 13.1 cannot, in Landlord's opinion, be made within two hundred seventy
(270) days after the occurrence of the damage or destruction, or if the damage
or destruction is occasioned by an act for which Landlord is not required under
this Lease to be insured, Landlord may, in its sole and absolute discretion,
elect to make such repairs within a reasonable time and in such event, unless
Tenant shall elect to terminate this Lease as provided below, this Lease shall
continue in effect and the Rent shall be abated in the manner provided in
Section 13.2 above. In all events Landlord's election to make such repairs must
be evidenced by written notice delivered to Tenant within sixty (60) days after
the occurrence of the damage or destruction. If Landlord elects not to make such
repairs and so notifies Tenant, then either party may, by ten (10) days' written
notice to the other, cancel this Lease as of the date of the occurrence of such
damage or destruction, which cancellation shall be effective only as to the
entirety of the particular portion
-22-
of the Premises that was damaged or destroyed (i.e., either the 0000 Xxxxxxxx
building or the 1550 Plymouth building). In addition, and notwithstanding any
desire or election by Landlord to make repairs or rebuild, Tenant, in its sole
discretion, may elect to terminate this Lease (only as to the entirety of the
particular Premises that was damaged or destroyed) by written notice to Landlord
if (i) such damage or destruction occurs during the last twelve (12) months of
the Term, or (ii) if in Landlord's reasonable opinion, such repairs cannot be
completed within two hundred seventy (270) days after the occurrence of such
damage or destruction or (iii) if Landlord fails to notify Tenant within sixty
(60) days following the date of such damage or destruction of Landlord's intent
to repair and restore the Premises.
13.4 No Claims. In no event shall Tenant be entitled to any claims,
---------
relief, remedies, compensation or damages for loss of use of the whole or any
portion of the Premises and/or for any inconvenience or annoyance occasioned by
any such damage, destruction, repair, reconstruction or restoration, Tenant's
sole remedy being the right to Rent abatement as provided for in Section 13.2
above. Tenant hereby waives any statutory rights of setoff and/or termination
that it may have (including but not limited to those contained in California
Civil Code Sections 1932, 1933(4) and 1942) which may arise by reason of any
partial or total destruction of the Premises.
ARTICLE 14
EMINENT DOMAIN
--------------
14.1 Total Condemnation. If the whole of the Premises is acquired or
------------------
condemned by eminent domain, inversely condemned or sold in lieu of condemnation
for any public or quasi-public use or purpose ("Condemned"), the Term of the
Lease shall terminate as of the date of title vesting in such proceeding and
Rent shall be adjusted as of the date of such termination.
14.2 Partial Condemnation. If any part (but not all) of the Premises is
--------------------
Condemned and such partial Condemnation renders the balance of the Premises not
reasonably usable for the normal business or operations of Tenant at the
Premises, as reasonably determined by Landlord and Tenant, then this Lease shall
terminate as of the date of title vesting in such proceeding (or such earlier
date as the Premises are rendered not reasonably usable for the normal business
of Tenant at the Premises) and Rent shall be adjusted to such date. If such
Condemnation is not sufficiently extensive to render the balance of the Premises
not reasonably usable for the normal business of Tenant as reasonably determined
by Landlord and Tenant, then Landlord shall, to the extent of available
Condemnation proceeds from the portion of the Premises Condemned, restore the
Premises to a condition comparable to its condition immediately prior to such
Condemnation less the portion thereof lost in such Condemnation, and this Lease
shall continue in full force and effect and, as of the date of such title
vesting, the Rent shall be equitably reduced as reasonably determined by
Landlord. If any parking areas within the Premises are Condemned to such an
extent that the Premises are not reasonably useable for the normal business of
Tenant as reasonably determined by Landlord and Tenant, then Tenant may elect to
terminate this Lease upon written notice to Landlord. Additionally, (i) if in
the reasonable opinion of Landlord the remaining portion of the Premises not
Condemned cannot reasonably or practicably be repaired or converted so as to
permit substantially the same use for which the Premises was used immediately
prior to the Condemnation, Landlord shall have the right to terminate this Lease
by
-23-
giving the Tenant at least sixty (60) days' written notice of such termination,
and (ii) if the Condemnation has a material adverse effect upon the means of
access to the Premises or twenty-five percent (25%) or more of the Premises will
be taken through Condemnation, then Tenant shall have the right to terminate
this Lease by giving Landlord at least sixty (60) days' notice thereof.
14.3 Landlord's Award. Subject to Section 14.4 below, if the Premises are
----------------
wholly or partially Condemned, Landlord shall be entitled to the entire award
paid for such Condemnation, and Tenant waives any right or claim to any part
thereof from Landlord or the condemning authority. No award for any partial or
entire taking shall be apportioned, and subject to Section 14.4 below, Tenant
hereby assigns to Landlord any award which may be made in such taking or
Condemnation.
14.4 Tenant's Award. Tenant shall have the right to claim and recover from
--------------
the Condemning authority, but not from Landlord, solely such compensation as may
be awarded or recoverable by Tenant in Tenant's own right for (a) the taking of
the unamortized or undepreciated value of any leasehold improvements owned by
Tenant that Tenant has the right to remove at termination of this Lease and that
Tenant elects not to remove, (b) reasonable removal and relocation costs for any
leasehold improvements that Tenant has the right to the remove and elects to
remove (if the Condemning authority approves of the removal), (c) loss of
goodwill, (d) relocation costs under Government Code Section 7262 (the claim for
which Tenant may pursue by separate action independent of this Lease), and (e)
any other amount in addition to the foregoing that does not in any manner or to
any extent reduce the amount of the award payable to Landlord. Tenant shall have
the right to negotiate directly with the Condemning authority for the foregoing
compensation.
14.5 Temporary Condemnation. If the whole or any part of the Premises
----------------------
shall be Condemned for any temporary public or quasi-public use or purpose, this
Lease shall remain in effect and Tenant shall be entitled to receive for itself
such portion or portions of any award made for such use with respect to the
period of the Condemnation which is within the Term. If a temporary Condemnation
remains in force at the expiration or earlier termination of the Term, Tenant
shall pay to Landlord a sum equal to the reasonable cost of performing any
obligations required of Tenant by this Lease with respect to the surrender of
the Premises, including without limitation, repairs and maintenance, and upon
such payment Tenant shall be excused from any such obligations. If a temporary
Condemnation is for an established period which extends beyond the Term, the
Lease shall terminate as of the date of occupancy by the Condemning authority,
and the awards shall be as provided in Sections 14.3 and 14.4.
14.6 Notice and Execution. Landlord shall, within five (5) business days
--------------------
of service of process in connection with any Condemnation or potential
Condemnation, give Tenant notice in writing thereof. Tenant shall promptly
execute and deliver to Landlord all instruments that may be reasonably required
to effectuate the provisions of this Article 14. Landlord may, without any
obligation or liability to Tenant, stipulate with any condemning authority for a
judgment of Condemnation without the necessity of a formal suit or judgment of
Condemnation, but only so long as Tenant's right to receive compensation or
damages in a separate proceeding for its trade fixtures, personal property and
relocation expenses is not negated or diminished thereby by this Section. Tenant
hereby waives any statutory rights of termination that it may have arising by
-24-
reason of the condemnation, including those contained in Section 1265.130 of the
California Code of Civil Procedure.
ARTICLE 15
ASSIGNMENT AND SUBLETTING
-------------------------
15.1 General Prohibition. Tenant shall not, either voluntarily,
-------------------
involuntarily or by operation of law, directly or indirectly, sell, hypothecate,
assign, encumber, mortgage, dispose of or otherwise transfer this Lease (or any
portion thereof), or any of Tenant's beneficial interest therein, or sublet the
Premises or any part thereof, or permit the same to be occupied by anyone other
than Tenant without the prior written consent of Landlord and any attempt to do
so without such prior written consent shall be null and void and shall
constitute an Event of Default hereunder. Subject to the provisions of this
Section 15.1 and Sections 15.2 and 15.3 below, Landlord agrees not to
unreasonably withhold its consent to any proposed assignment or sublease of this
Lease, provided that the proposed assignee or subtenant (i) is reasonably
satisfactory to Landlord as to its creditworthiness, character and business
reputation, (ii) will occupy the Premises solely for the uses permitted under
this Lease and (iii) in the case of an assignment, assumes and agrees to be
bound and directly responsible for all of Tenant's obligations hereunder.
Landlord's consent to any such assignment or sublease shall in no event be
construed as releasing Tenant from any or all of its duties, liabilities or
obligations under this Lease, including, without limitation, the obligation to
pay Rent and all other sums due under this Lease, nor as relieving Tenant from
the requirement of obtaining Landlord's prior written consent to any further
assignment or subletting. Notwithstanding any contrary provisions of this
Article 15 or any contrary provisions of Article 15 of the Xxxxxxx Lease, (a)
during the Term and any Extended Term(s), Tenant may sublease up to, but not
more than, an aggregate of Twenty Thousand (20,000) rentable square feet of
space within the Premises and/or the Xxxxxxx Premises (which 20,000 rental
square feet may, at Tenant's option, include up to, but not more than, Twelve
Thousand (12,000) rentable square feet in the aggregate in the Xxxxxxx
Premises), upon prior written notice to Landlord but without Landlord's consent,
to one (1) or more Tenant Subsidiaries (as defined in Section 1.17 above) and
(b) Tenant may assign this Lease or sublease all or a portion of the Premises,
upon prior written notice to Landlord but without Landlord's consent, to a
Tenant Affiliate (as defined in Section 1.16 above) (with the foregoing
transactions being referred to in this Article 15 as "Internal Transaction.")
Any assignment or sublease to a Tenant Affiliate or a Tenant Subsidiary in any
Internal Transaction shall not release or relieve Tenant of any of its duties,
liabilities or obligations under this Lease including, without limitation, the
obligation to pay Rent and all other charges under this Lease and (x) with
respect to an assignment, such Tenant Affiliate shall assume, in full, all of
the obligations of Tenant under this Lease pursuant to assumption documentation
reasonably acceptable to Landlord and (y) with respect to a sublease, such
Tenant Affiliate or Tenant Subsidiary and the proposed sublease shall comply
with all of the provisions of Section 15.7 set forth below.
15.2 Lease Termination. If at any time during the Term or any Extended
-----------------
Term(s) of the Lease, Tenant determines that it wishes to assign or sublease all
or any portion of the Premises to any person or entity prior to marketing such
space to a proposed assignee or subtenant, Tenant shall first deliver a written
notice of the foregoing to Landlord. Landlord shall have the right, in
Landlord's sole and absolute discretion, to be exercised within fifteen (15)
-25-
business days following Landlord's receipt of Tenant's written notice, to either
(i) subject to the provisions of this Article 15, permit Tenant to proceed with
its plans to assign this Lease or sublet the portion of the Premises which was
the subject of Tenant's written notice or (ii) (A) in the case of a proposed
assignment or sublease of more than sixty percent (60%) of the total rentable
square footage of the Premises, terminate this Lease as to the entire Premises
and release Tenant from its remaining obligations hereunder (other than Tenant's
obligations hereunder which expressly survive the termination of the Lease), (B)
in the case of a proposed assignment or sublease of less than sixty percent
(60%) of the Premises but more than fifty percent (50%) of the total rentable
square footage of either of the two (2) buildings comprising the Premises,
terminate this Lease as to such building ("recaptured building"), release Tenant
from its obligations under this Lease as to such recaptured building (other than
Tenant's obligations under the Lease which expressly survive the termination of
the Lease) and amend the Lease to reflect the reduction in the rentable square
footage of the remaining Premises or (C) in the case of the proposed assignment
or sublease of less than sixty percent (60%) of the Premises and less than fifty
percent (50%) of either of the buildings comprising the Premises, terminate the
Lease with respect to the portion of the Premises that Tenant wishes to sublease
and amend the Lease to reflect the reduction in the rentable square footage of
the remaining Premises; provided that the foregoing termination rights shall not
apply to an Internal Transaction (as defined in Section 15.1 above) (but shall
apply to the subleasing of any space in the Premises and the Xxxxxxx Premises in
excess of 20,000 rentable square feet in the aggregate to Tenant Subsidiaries);
and provided further, that Tenant shall have the right, subject to Landlord's
right (a) to reasonably consent to the proposed subtenant pursuant to Sections
15.1 above and 15.3 below, (b) to receive reimbursement of Landlord's costs
pursuant to Section 15.6 below and (c) to approve the form of sublease agreement
pursuant to Section 15.7 below, to enter into a sublease (and/or a succeeding
replacement sublease of the same space) of up to, but not more than, an
aggregate of Ten Thousand (10,000) rentable square feet of space within the
Premises and/or the Xxxxxxx Premises for a term not to exceed twenty-four (24)
months without giving Landlord the right to terminate the Lease as to such
subleased portion of the Premises. If Landlord elects not to recapture the
Premises or portion thereof which was the subject of Tenant's written notice or
fails to respond in writing to Tenant within such fifteen (15) business day
period, then for a period of six (6) months thereafter, subject to the
provisions of this Article 15, Tenant may proceed with its plans to attempt to
assign or sublease the portion of the Premises which was the subject of Tenant's
written notice.
15.3 Assignment Information. Provided Tenant has first complied with the
----------------------
provisions of Section 15.2 above, if Tenant desires at any time to assign this
Lease or to sublet the Premises or any portion thereof (other than to a Tenant
Affiliate), Tenant shall first notify Landlord of its desire to do so and shall
submit in writing to Landlord (i) the name of the proposed subtenant or assignee
(including a Tenant Subsidiary); (ii) the nature of the proposed subtenant's or
assignee's business to be carried on in the Premises (including a Tenant
Subsidiary); (iii) the terms and conditions of the proposed sublease or
assignment (including complete and accurate copies of all proposed assignment or
sublease documentation) including a sublease to a Tenant Subsidiary; (iv) such
financial and business information as Landlord may reasonably request concerning
the proposed subtenant or assignee (other than a Tenant Subsidiary) including
information concerning the proposed subtenant's or assignee's use, handling,
storage and disposal of Hazardous Materials; and (v) such other information as
Landlord may reasonably request. If Tenant claims that any assignment or
subleasing constitutes an Internal Transaction,
-26-
Tenant shall provide to Landlord all information required to substantiate such
assignment or subleasing as a bona fide Internal Transaction. Landlord shall
grant or withhold its consent to any proposed assignment or subletting within
ten (10) business days from the date of receiving full and complete copies of
all of the information, materials and documents set forth in this Section 15.3.
15.4 Rent Increase. The Monthly Base Rent for the portion of the Premises
-------------
assigned or sublet (the "Applicable Portion") shall be increased to the Monthly
Base Rent for such Applicable Portion prior to such assignment or subletting
plus one hundred percent (100%) of the amount by which any rental payment or
other consideration of any nature whatsoever received by Tenant from the
assignee or subtenant including any Tenant Affiliate or Tenant Subsidiary
(whether received before or after the effective date of such approved assignment
or subleasing) for such Applicable Portion exceeds the Monthly Base Rent paid by
the Tenant to Landlord for such Applicable Portion; provided, however, Tenant
may offset against the increase in Monthly Base Rent hereunder solely (a)
Tenant's actual and reasonable third party brokerage fees and marketing costs
incurred in such assignment or sublease transaction, (b) Tenant's actual and
reasonable attorneys' fees incurred in such assignment or sublease transaction,
and (c) and the costs of reasonable alterations to the Applicable Portion
actually installed or paid for by Tenant in connection with the occupancy of the
Applicable Portion by such assignee or subtenant (amortized over the useful life
of such alternations with interest thereon at Eight Percent (8%) per annum). For
purposes of this Section 15.4, the term "rental payment" shall mean all
consideration paid or given, directly or indirectly, to Tenant for the use of
the Premises or any portion thereof and the term "consideration" shall mean and
include money, services, property or any other thing of value such as warrants,
stock or securities, payment of costs, cancellation of indebtedness, discounts,
rebates and the like and including, without limitation, key money and bonus
money given to Tenant for the use of the Premises or any portion thereof,
whether paid to Tenant before or after the effective date of the assignment or
sublease. Notwithstanding the foregoing, under no circumstances shall Landlord
be entitled to (a) any security deposits or other sums given to Tenant as
security for the assignee's or subtenant's obligations or (b) any portion of any
bona fide consideration paid for any assets of Tenant (other than Tenant's
leasehold interest hereunder and separate and apart from any consideration paid
for the assignment and subleasing) in connection with the sale or other transfer
of such assets by Tenant. "Sublet" and "sublease" shall include a sublease as to
which Tenant is sublessor and any sub-sublease or other subsubtenancy,
irrespective of the number of tenancies and tenancy levels between the ultimate
occupant and Landlord, as to which Tenant receives any consideration, as defined
herein, and Tenant shall require on any sublease which it executes that Tenant
receive the profit from all subsubtenancies, irrespective of the number of
levels thereof. Any rental payment or other consideration which is to be passed
through to Landlord by Tenant shall be paid to Landlord within five (5) days
following receipt by Tenant and shall be paid in cash, irrespective of the form
in which received by Tenant from a subtenant or assignee. Tenant acknowledges
and agrees that the purpose of this Section 15.4 is to ensure that Landlord
receives one hundred percent (100%) of any profit (after subtracting Tenant's
costs and fees described in clauses (a) through (c) hereinabove) from any
assignment or sublease of the Premises (including, without limitation, from
Internal Transactions) that Tenant receives over Monthly Base Rent payable by
Tenant hereunder.
-27-
15.5 Stock Transfers. If Tenant is a corporation the stock of which is not
---------------
traded on the NYSE, AMEX or NASDAQ exchanges, or if Tenant is a partnership,
limited liability company or unincorporated association, the sale, transfer,
assignment, pledge or hypothecation, other than in connection with any IPO, of
any stock, interest, membership rights or similar interest in such corporation,
partnership, limited liability company or association (as the case may be) in
the aggregate in excess of twenty-five percent (25%) of any class or type of
stock of Tenant or interest in Tenant shall be deemed an assignment within the
meaning of this Article 15 and the corporation, partnership, limited liability
company or association as it exists after such sale, transfer, assignment,
pledge or hypothecation shall be deemed to be a successor and assign of the
Tenant.
15.6 Costs. In the event that Tenant shall submit a written notice to
-----
Landlord under Section 15.2 above or assign or sublet the Premises or request
the consent of Landlord to any assignment or subletting, Tenant shall pay
Landlord's reasonable costs and expenses incurred in connection with each such
transaction (including any Internal Transaction), including reasonable
attorneys, architects, engineers or other consultants fees, within ten (10)
business days following written demand therefor from Landlord accompanied by
invoices reasonably substantiating such costs, whether Landlord terminates this
Lease (or any portion thereof), consents to such assignment or subletting or
withholds its consent thereto.
15.7 Subletting Terms. The following terms and conditions shall apply to
----------------
any subletting by Tenant of all or any part of the Premises (including, without
limitation, any subleasing to any Tenant Affiliate or Tenant Subsidiary) and
shall be deemed included in all subleases whether or not expressly incorporated
therein:
15.7.1 Tenant assigns and transfers to Landlord all of Tenant's
interest in all rentals and income arising from any sublease of the Premises
heretofore or hereafter made by Tenant, and Landlord may collect such rent and
income and apply the same toward Tenant's obligations under this Lease;
provided, however, that until a default (following the expiration of any
applicable grace or cure periods without cure) shall occur in the performance of
Tenant's obligations hereunder, Tenant may receive and collect the rents
accruing under such sublease. Landlord shall not, by reason of this or any other
assignment of such sublease to Landlord or by reason of the collection of rents
from a subtenant, be deemed liable to the subtenant for any failure of Tenant to
perform and comply with any of Tenant's obligations to such subtenant. Tenant
hereby irrevocably authorizes and directs any such subtenant, upon receipt of a
written notice from Landlord stating that a default (following the expiration of
any applicable cure grace period without cure) exists in the performance of
Tenant's obligations under this Lease, to pay to Landlord the rents and all
other sums due and to become due under the sublease until such default has been
cured by Tenant. Tenant agrees that such subtenant shall have the right to rely
upon any such statement and request from Landlord, and that such subtenant shall
pay such rents or other sums to Landlord without any obligation or right to
inquire as to whether such default exists and notwithstanding any notice, demand
or claim from Tenant to the contrary. Tenant shall have no right or claim
against said subtenant or Landlord for any such rents or sums so paid by
subtenant to Landlord.
15.7.2 No such sublease of the Premises entered into by Tenant shall
be effective unless and until it has been approved in writing by Landlord. An
approved sublease shall not be
-28-
changed, supplemented or modified, in any manner, without Landlord's reasonable
prior written consent. Any subtenant shall, by virtue of entering into a
sublease under this Lease, be deemed, for the benefit of Landlord, to have
assumed and agreed to perform and comply with each and every obligation herein
to be performed by Tenant with respect to the subleased space other than such
obligations as are contrary to or inconsistent with provisions contained in a
sublease to which Landlord has expressly consented in writing.
15.7.3 In the event Tenant shall default (following the expiration of
any applicable cure period without cure) in the performance of any of its
obligations under this Lease, Landlord, at its option and without any obligation
to do so, may require any subtenant to attorn to Landlord, in which event
Landlord shall undertake the obligations of Tenant under such sublease from the
time of the exercise of said option to the termination of such sublease;
provided, however, Landlord shall not be liable for any prepaid rents or
security deposit paid by such subtenant to Tenant or for any prior default of
Tenant under such sublease.
ARTICLE 16
ACCESS AND RESERVED RIGHTS
--------------------------
16.1 Access Rights. Landlord and its agents, representatives and
-------------
contractors shall at all reasonable times have the right, but not the
obligation, to enter the Premises to (i) inspect the same; (ii) to show the
Premises to prospective purchasers or tenants (as to prospective tenants, only
during the last twelve (12) months of the Term or Extended Term); (iii) to post
notices of nonresponsibility; and (iv) to alter, improve, maintain or repair the
Premises or any other portion thereof, to test and/or monitor groundwater or
investigate the environmental conditions of the Premises on an ongoing basis as
determined by Landlord in its sole discretion and to install, maintain, repair,
replace and relocate pipes, ducts, conduits, wires, meters and other equipment
within the demising walls, floors, bearing columns, roofs and ceilings of the
Premises, and in the course of such work to close entrances, doors, corridors,
elevators or other Building facilities or temporarily xxxxx their operation, all
without being deemed an eviction or constructive eviction of Tenant and without
abatement of Rent (other than as expressly provided below), and Landlord may for
such purposes erect scaffolding and other necessary structures where reasonably
required by the character of the work to be performed, provided that Landlord,
in connection with each and all of the foregoing, shall use all reasonable
efforts to ensure that the business of Tenant shall be interfered with as little
as is reasonably practicable. If the negligence or willful misconduct of
Landlord or any Landlord Party in carrying out any action pursuant to this
Section 16.1 unreasonably interferes with the conduct of Tenant's business in
the Premises, then Tenant shall be entitled to equitable rent abatement to the
extent the Premises are unusable by Tenant in the conduct of its normal business
therein commencing on the second (2/nd/) business day of such interference and
continuing until such interference is sufficiently remedied to permit Tenant to
recommence its normal business operations in the Premises. Tenant hereby waives
any claim for damages for any injury or inconvenience to or interference with
Tenant's business or loss of quiet enjoyment of the Premises caused by
Landlord's entry on the Premises in accordance with this Section 16.2 (but not
for injury or damage to persons or Tenant's property in the Premises caused by
Landlord's negligence or willful misconduct). For each of the aforesaid
purposes, Landlord shall at all times have and retain a key, pass code for
security devices or other device and be provided with any required information
with which to unlock all of the doors in, upon and
-29-
about the Premises and gain access to the Premises, excluding Tenant's vaults,
safes, files, security cabinets, and other areas designated as secure by Tenant,
the location and/or installation of which have been previously approved by
Landlord. Landlord shall have the right to use any and all means which Landlord
may deem proper to open said doors in an emergency in order to obtain entry to
the Premises, and any entry to the Premises obtained by Landlord by any of said
means shall not under any circumstances be construed or deemed to be a forcible
or unlawful entry into, or a detainer of, the Premises, or any eviction of
Tenant from the Premises or any portion thereof. No provision of this Lease
shall be construed as obligating Landlord to perform any repairs, alterations or
decoration except as otherwise expressly provided in this Lease. Notwithstanding
anything to the contrary in this Section 16.1 or elsewhere in this Lease,
Landlord and Landlord's agents, representatives and contractors, except in the
case of emergency (where no notice is required), shall provide Tenant with at
least one business day notice prior to each entry of the Premises (except,
however, in the case where Landlord's proposed entry is for the purpose of
performing non-emergency work in the Premises, Landlord shall provide Tenant
with at least two (2) business days prior written notice). If the purpose of
such access is to perform any work in the Premises, said notice from Landlord
shall include a description of the proposed work, the location of the proposed
work the approximate duration of the proposed work, and the names of the persons
to perform the proposed work. Any such entry by Landlord or Landlord's agents,
representatives and contractors, shall comply with all reasonable security
measures of Tenant (including, without limitation, written sign-in, badging, and
accompaniment by a representative of Tenant) and shall not impair Tenant's
operations more than reasonably necessary.
16.2 Reserved Rights. Landlord further reserves the right from time to
---------------
time to change the boundary lines of the lot on which the Premises stands, to
record parcel maps and subdivision maps, and to make other reasonable changes
and to grant other reasonable rights to the exterior portions of the Premises,
including, without limitation, the granting of easements, servitudes, rights of
way and rights of ingress and egress and similar rights to users of adjacent
parcels, utility companies, governmental agencies or other tenants, provided the
same do not interfere with the use, occupancy or quiet enjoyment of the Premises
by Tenant or diminish any of Tenant's rights or increase its obligations under
this Lease. Without limiting the scope of or the generality of foregoing
restrictions on Landlord's rights under this Section 16.2, under no
circumstances may Landlord grant rights which would reduce the parking available
to Tenant hereunder.
ARTICLE 17
SUBORDINATION AND ATTORNMENT
----------------------------
17.1 Subordination. This Lease is junior, subject and subordinate to all
-------------
existing mortgages, deeds of trust, security assignments, covenants, conditions
and requirements and other security instruments of any kind now encumbering the
Premises or any portion thereof including any renewals, amendments,
modifications, replacements or extensions of the same. Landlord reserves the
right to place new liens and other new encumbrances on the Premises or any part
thereof or interest therein superior in lien and effect to this Lease subject to
Tenant's receipt of commercially reasonable non-disturbance protection in a form
similar to that attached to this Lease as Exhibit E with such changes as may be
---------
reasonably requested by Landlord's
-30-
lender or the other party to the agreement (the "Nondisturbance Agreement").
Provided Tenant concurrently or earlier receives an executed Nondisturbance
Agreement from the lienholder or encumbrance, Tenant agrees to execute,
acknowledge and deliver within ten (10) business days following written demand
from Landlord such further instruments evidencing the subordination of this
Lease to any new liens or encumbrances as may be reasonably requested by
Landlord. Notwithstanding such subordination, Tenant's right to peaceful and
quiet possession of the Premises shall not be disturbed by the foreclosure or
termination of future liens or encumbrances so long as Tenant shall pay the Rent
and observe and perform all of the provisions of this Lease to be observed and
performed by Tenant, unless this Lease is terminated pursuant to specific
provisions relating to termination contained herein. In the event of the
foreclosure or termination of any such lien or encumbrance, or the transfer of
title to the Premises, Tenant shall attorn to the then owner who owns or
acquires title to the Premises and shall recognize such owner as Landlord under
this Lease. Tenant agrees to execute and deliver within ten (10) business days
following written demand from such owner any instruments reasonably required to
evidence this attornment.
17.2 Estoppel Certificates. Tenant shall at any time and from time to time
---------------------
upon not less than ten (10) business days' prior written notice by Landlord,
execute, acknowledge and deliver to Landlord a statement in writing certifying
that this Lease is unmodified and in full force and effect (or if there have
been modifications, that the same are in full force and effect as modified and
stating the modifications), the dates to which the Monthly Base Rent and other
charges have been paid in advance, if any, and the amount of the undrawn portion
of the Letter of Credit, and stating whether or not to the actual knowledge of
Tenant, Landlord or Tenant is in default in the performance of any covenant,
agreement or condition contained in this Lease and, if so, specifying each such
default of which Tenant may have actual knowledge, and stating such other
matters of which Tenant may have actual knowledge concerning the status of this
Lease as Landlord may reasonably request. Tenant acknowledges that any such
statement delivered pursuant to this Section may be relied upon by any
prospective purchaser of the Premises or any mortgagee, ground lessor or other
like encumbrance thereof or any assignee of any such encumbrance upon the
Premises. Tenant's failure to deliver such statement within such time shall
constitute a default by Tenant under this Lease and additionally shall be
binding and conclusive upon Tenant (i) that this Lease is in full force and
effect, without modification except as may be represented by Landlord, (ii) that
there are no uncured defaults in Landlord's performance or rights of offset
against Tenant's obligations hereunder, and (iii) that not more than one month's
rent has been paid in advance.
ARTICLE 18
TRANSFER OF PREMISES; QUIET ENJOYMENT
-------------------------------------
Any sale, transfer, conveyance or other disposition by Landlord of
Landlord's fee interest in the Premises shall operate to release Landlord from
any and all liabilities, obligations and duties under this Lease accruing from
and after the date fee title to the Premises is conveyed of record to the
transferee. Subject to the provisions of Article 17 hereof, Tenant's right to
peaceful and quiet possession of the Premises shall not be disturbed so long as
Tenant shall pay all Rent and observe and perform all of the provisions of this
Lease to be observed and
-31-
performed by Tenant, unless this Lease is terminated pursuant to specific
provisions contained herein allowing for such termination.
ARTICLE 19
NONLIABILITY AND INDEMNIFICATION OF LANDLORD; INSURANCE
-------------------------------------------------------
19.1 Indemnification. Except for Losses (defined below) caused by the
---------------
willful misconduct of, violation of law by, breach of this Lease or any
provision hereof by, or the negligence of Landlord or its agents, employees,
contractors, licensees or invitees, Tenant agrees to indemnify, defend and hold
harmless Landlord and its directors, officers, employees, agents, partners,
trustees, parents, subsidiaries, shareholders, affiliates, lenders, successors
and assigns from and against any and all claims, damages, liabilities, losses,
fines, penalties, actions or causes of action, judgments, costs and expenses,
including attorneys' fees, investigation costs and costs of court (if any)
(collectively, "Losses"), whether foreseeable or unforeseeable, directly or
indirectly arising out of or relating to, in whole or in part, Tenant's or
Tenant Parties use of the Premises or the conduct of Tenant's business at the
Premises or from any activity, work, or thing done, permitted or suffered by
Tenant or Tenant Parties in or about the Premises, and shall further indemnify,
defend and hold harmless such parties from and against any and all such claims
arising from any breach or default in the performance of any obligation on
Tenant's part to be performed under the terms of this Lease, or arising from the
negligence of Tenant or the Tenant Parties during the Term or any Extended Term,
and from and against all costs, attorneys' fees, expenses, damages, judgments,
actions and liabilities incurred in or concerning any such claim or any action
or proceeding brought thereon. If any action or proceeding is brought against
Landlord by reason of any such claim, Tenant, upon notice from Landlord, shall
immediately defend Landlord at Tenant's sole expense by counsel reasonably
satisfactory to Landlord. The indemnity obligations of Tenant shall not be
limited by available insurance proceeds. Tenant's indemnification and defense
obligations set forth in this Section 19.1 shall survive the expiration or
earlier termination of the Lease.
19.2 Waiver of Claims. Tenant, as a material part of the consideration to
----------------
Landlord, hereby assumes all risk of damage to property or injury to persons,
including Tenant Parties in, upon or about the Premises from any cause
whatsoever, excepting Landlord's or its agents', employees', contractors',
licensees' or invitees' willful misconduct, violation of law, breach of this
Lease or any provision hereof, or negligence, and Tenant hereby waives all known
claims in respect thereof against Landlord. Tenant's obligations set forth in
this Section 19.2 shall survive the expiration or earlier termination of the
Lease.
19.3 Insurance Obligation. Tenant hereby agrees to obtain, maintain and
--------------------
keep in full force and effect at all times during the Term and any Extended Term
of this Lease, at Tenant's sole cost and expense, for the protection of Tenant
and Landlord, and, if required by Landlord, Landlord's lenders, policies of
insurance issued by a responsible carrier or carriers qualified to do business
in the State of California and maintaining a rating of at least "A VII" or
better in Best's Insurance Guide and in a form reasonably acceptable to Landlord
which afford the following:
-32-
19.3.1 Worker's Compensation Insurance in compliance with California
law and Employer's Liability Insurance with limits of not less than One Million
Dollars ($1,000,000) per occurrence and aggregate. Tenant on behalf of itself
and all persons and parties claiming under or through Tenant, including, without
limitation, Tenant's insurance carriers, waive all rights of subrogation which
Tenant may have against Landlord under applicable worker's compensation
statutes.
19.3.2 Commercial General Liability Insurance protecting Landlord and
Tenant against claims for death, bodily injury, personal injury and property
damage based upon, relating to or arising out of Tenant's and Tenant Parties'
leasing, use, occupancy, repair and maintenance of the Premises and all areas
appurtenant thereto or from the conduct of Tenant's business or profession or
anything done, permitted or suffered by Tenant in or about the Premises and all
areas appurtenant thereto. Such Commercial General Liability Insurance shall be
written on an occurrence basis and shall provide for a combined single limit of
not less than Two Million Dollars ($2,000,000) per occurrence per location and
shall include, without limitation, Blanket Contractual Liability, Broad Form
Property Damage, Fire Legal Liability, Personal Injury, Completed
Operations/Products Liability (if applicable), Owned and Non-Owned Automobile
Coverage, (included or in a separate policy, with limits of not less than Two
Million Dollars ($2,000,000) per occurrence and aggregate), Protective and/or
Contingent Liability Insurance, Additional Insured-Managers or Landlords of
Premises Endorsement and an Amendment of the Pollution Exclusion for damage
caused by heat, smoke or fumes or from a hostile fire. The policy shall not
contain any intra-insured exclusions as between insured persons and
organizations. The policy shall specifically include coverage for liability
assumed under this Lease as an "insured contract" and shall insure all of
Tenant's indemnity obligations under this Lease including, without limitation,
Tenant's indemnity obligations under Section 19.1 above. The limits of insurance
carded by Tenant as set forth above shall not, however, limit the liability of
Tenant under this Lease or relieve Tenant of any liability under this Lease.
19.3.3 "All Risk" Insurance, including Fire and Extended Coverage,
Vandalism and Malicious Mischief and Sprinkler Leakage insurance in an amount
equal to the full replacement cost of all of Tenant's initial Tenant
Improvements constructed by or for Tenant pursuant to the Work Letter, all
improvements, additions, alterations and trade fixtures installed within the
Premises by Tenant and all of Tenant's fixtures, furnishings, equipment and
personal property, including, without limitation, all Remaining Furniture, with
a commercially reasonable deductible. The proceeds of the foregoing insurance
shall be used by Tenant solely for the replacement of Tenant's initial Tenant
Improvements and its additions, alterations and trade fixtures installed within
the Premises, and Tenant's fixtures, furnishings, equipment and personal
property, including, without limitation, all Remaining Furniture.
19.4 Landlord's Insurance Obligations. Subject to Tenant's compliance with
--------------------------------
Tenant's payment obligations under Article 5 of the Lease with respect to
Landlord's Insurance Premiums, Landlord hereby agrees to obtain, maintain and
keep in full force and effect at all times during the term and any Extended
Term, for the protection of Landlord and, if required by Landlord, Landlord's
lenders, policies of insurance issued by a responsible carrier or carriers
qualified to do business in the State of California and maintaining a rating of
at least "A VII" or better in Best's Insurance Guide which afford the following
coverages:
-33-
19.4.1 "All Risk" Insurance with commercially reasonable deductibles
including, without limitation, Fire and Extended Coverage, a Change in Condition
Endorsement with limits adequate to rebuild the Premises in compliance with then
applicable laws, codes and ordinances, Vandalism and Malicious Mischief,
Sprinkler Leakage insurance, and in Landlord's sole discretion, Flood Insurance
and/or Earthquake Insurance, in the name of and for the benefit of Landlord, and
with all proceeds payable to Landlord (and/or any of Landlord's lenders as
Landlord may direct) in an amount equal to the full replacement cost of the
Premises (as the same may be increased from time to time) including, without
limitation, loss or damage to the Premises, but excluding coverage for Tenant's
initial Tenant Improvements constructed by or for Tenant pursuant to the Work
Letter and excluding coverage for any improvements, alterations, additions,
trade fixtures, equipment, furnishings, fixtures and personal property
(including the Remaining Furniture) installed within the Premises by or for
Tenant. Tenant shall be liable for the payment of any deductible amount in the
event of any loss covered by the insurance required under this Section 19.4.1.
19.4.2 Commercial General Liability Insurance protecting Landlord
against claims for death, bodily injury, personal injury and property damage
based upon, relating to or arising out of Landlord's leasing of the Premises and
all areas appurtenant thereto or anything done, permitted or suffered by
Landlord in or about the Premises and all areas appurtenant thereto. Such
Comprehensive General Liability Insurance shall be written on an occurrence
basis and shall provide for a combined single limit of not less than Five
Million Dollars ($5,000,000) per occurrence per location and shall include,
without limitation, Blanket Contractual Liability, Broad Form Property Damage,
Fire Legal Liability, Personal Injury, Completed Operations/Products Liability,
if applicable, Owned and Non-Owned Automobile Coverage (included or in a
separate policy, with limits of not less than Two Million Dollars ($2,000,000)
per occurrence and aggregate), Protective and/or Contingent Liability Insurance,
Additional Insured-Managers or Landlords of Premises Endorsement and an
Amendment of the Pollution Exclusion for damage caused by heat, smoke or fumes
or from a hostile fire. Tenant shall be named as an additional insured on
Landlord's Commercial General Liability Insurance Policy.
19.4.3 Business or Rental Interruption Insurance in the name of and
for the benefit of Landlord and with all proceeds payable to Landlord (and/or
any of Landlord's lenders as Landlord may direct), insuring the loss of the Rent
and other charges payable by Tenant to Landlord under this Lease (including all
Monthly Base Rent, Property Taxes, Insurance Premiums, and any scheduled rental
increases for a period not to exceed twelve (12) months). Said insurance shall
contain an agreed valuation provision in lieu of any coinsurance clause, and the
amount of coverage shall be adjusted annually to reflect the projected Rent,
Property Taxes, Insurance Premiums and other expenses, if any, otherwise payable
by Tenant. Tenant shall be liable for any deductible amount in the event of any
loss covered by the insurance required under this Section 19.4.3.
Any insurance required to be carried by Landlord under Sections 19.4.1, 19.4.2
or 19.4.3 above may be carried by Landlord under a blanket insurance policy
covering the Premises and any of Landlord's other locations.
-34-
19.5 Policy Terms. All liability insurance required of Tenant under this
------------
Article (except Worker's Compensation) shall be primary coverage and shall not
be contributing with any other liability insurance maintained by Landlord.
19.6 Insurance Certificates. Tenant shall deliver to Landlord at least ten
----------------------
(10) business days prior to the time any insurance coverage is first required to
be carried by Tenant, and thereafter at least thirty (30) days prior to
expiration of such policy, certificates of insurance evidencing the required
coverages with limits not less than those specified in Section 19.3 above. The
certificate evidencing the insurance required pursuant to Section 19.3.2 above
shall name Landlord and each of Landlord's lenders (if any), as additional
insureds, and the certificate evidencing the insurance required pursuant to
Section 19.4.2 above shall name Tenant as additional insured. The certificates
to be delivered by Tenant shall expressly provide that not less than thirty (30)
days' prior written notice shall be given to Landlord in the event of
cancellation or non-renewal of the coverages evidenced by such certificates.
Upon written request of Landlord, Tenant shall deliver full and accurate copies
of all insurance policies required of it by this Lease.
19.7 Disclaimer. Landlord makes no representation that the limits or form
----------
of insurance coverage specified to be carried by Tenant under the terms of this
Lease are adequate to protect Tenant against Tenant's undertaking under this
Article 19.
ARTICLE 20
WAIVER OF SUBROGATION
---------------------
Notwithstanding anything to the contrary in this Lease, Tenant and
Landlord each hereby, on behalf of itself and all persons and parties claiming
under or through it, including without limitation its insurance carrier(s),
waive any right of recovery or claim against the other for any damage to or
destruction of any property located in or about the Premises which results from
or arises out of any casualty or event insured or required to be insured
hereunder by any casualty and/or property insurance policy carried by such
waiving party, regardless of the cause or origin of such casualty or event,
including without limitation, the negligence of Tenant or Landlord. Any policy
or policies of fire, extended coverage or similar casualty insurance or of
liability insurance that either party obtains in connection with the Premises or
Tenant's personal property therein shall include a clause or endorsement denying
the insurer and waiving any rights of subrogation against the other party to the
extent rights have been waived by the insured prior to the occurrence of injury
or loss.
ARTICLE 21
ATTORNEYS' FEES
---------------
In the event of any legal action or proceeding brought by either
party against the other arising out of this Lease, the prevailing party (by way
of settlement or final judgment) shall be entitled to recover reasonable
attorneys' fees and costs incurred in such action and such amount shall be
included in any judgment rendered in such proceeding. The provisions contained
in this Article 21 shall survive the expiration or earlier termination of this
Lease.
-35-
ARTICLE 22
WAIVER
------
No waiver by either party hereto of any provision of this Lease or of
any breach by the other party hereunder shall be deemed to be a waiver of any
other provision hereof, or of any subsequent breach by the other party of the
same or any other provision. Landlord's consent to or approval of any act by
Tenant requiring Landlord's consent or approval shall not be deemed consent to
or approval of any subsequent act of Tenant. No act or thing done by Landlord or
Landlord's agents during the Term of this Lease shall be deemed an acceptance or
a surrender of the Premises, unless done in writing signed by Landlord. The
delivery of the keys to any employee or agent of Landlord shall not operate as a
termination of the Lease or a surrender of the Premises. The acceptance of any
Rent by Landlord following a breach of this Lease by Tenant shall not constitute
a waiver by Landlord of such breach or any other breach unless such waiver is
expressly stated in a writing signed by Landlord.
ARTICLE 23
NOTICES
-------
Any notice, consent, approval, request for consent or approval of or
communication to Landlord or Tenant required or permitted to be given under this
Lease shall be effectively given only if in writing and (i) mailed by United
States Registered or Certified Mail, postage prepaid, return receipt requested,
or (ii) sent by a nationally recognized courier service (e.g., Federal Express)
for next day business delivery, or (iii) personally delivered or served against
receipted copy, or (iv) transmitted via facsimile, in each case addressed to the
recipients at their addresses (or fax numbers in the case of facsimile
transmissions) set forth in Items 3 and 5 of the Basic Lease Provisions. Either
party shall have the right to change the address to which notices shall
thereafter be sent by giving notice to the other party as aforesaid. Notices
given in the aforesaid manner shall be deemed delivered on the date of scheduled
delivery, if sent by courier service, or three (3) days after sending, if sent
by mail, or upon personal delivery or service, if personally delivered or
served, or upon the date of successful facsimile transmission, if sent via
facsimile.
ARTICLE 24
BANKRUPTCY
----------
In no event shall this Lease be assigned or assignable by operation of
law and in no event shall this Lease be an asset of Tenant in any receivership,
bankruptcy, insolvency, or reorganization proceeding.
-36-
ARTICLE 25
DEFAULT AND REMEDIES
--------------------
25.1 Events of Default. The occurrence of any of the following shall
-----------------
constitute a material default and breach of this Lease by Tenant (each, an
"Event of Default"):
25.1.1 Nonpayment of Rent. Any failure by Tenant to pay Rent or
------------------
Additional Rent or to make any other payment required to be made by Tenant
hereunder on the due date, where such failure continues for three (3) business
days after written notice from Landlord to Tenant demanding such payment;
25.1.2 Abandonment. Abandonment of the Premises by Tenant;
-----------
25.1.3 Breach of Other Covenants. Any failure by Tenant to observe
-------------------------
and perform any obligation, covenant or provision of this Lease to be observed
or performed by Tenant other than those matters specified in Sections 25.1.1 and
25.1.2 above and 25.1.8, 25.1.9, 25.1.10 or 25.1.11 below, where such failure
continues for thirty (30) days after written notice by Landlord to Tenant. If
the nature of such default is such that it cannot reasonably be cured within
such thirty (30) day period Tenant shall not be deemed to be in default if
Tenant shall within such period commence such cure and thereafter diligently
prosecute the same to completion;
25.1.4 False Statement. Any warranty or representation made by Tenant
---------------
in this Lease proves to be false or misleading in any material respect when
made, including any Financial Statements;
25.1.5 Insolvency. Tenant or any Guarantor becomes insolvent, as
----------
defined in the Federal Bankruptcy Code, admits in writing its insolvency or its
present or prospective inability to pay its debts as they become due, permits or
suffers a judgment, attachment, execution or judicial seizure to exist against
it which materially adversely affects Tenant's ability to conduct its business
in the ordinary course (unless enforcement thereof is stayed pending appeal)
that is not discharged or dismissed within thirty (30) days, makes an assignment
for the benefit of creditors, or any class thereof, for purposes of effecting a
moratorium upon or extension or composition of its debts, proposed any such
moratorium, extension or composition, or commences or proposes to commence any
bankruptcy, reorganization or insolvency proceeding, or other proceeding under
any federal, state or other law for the relief of debtors;
25.1.6 Involuntary Bankruptcy. Tenant fails to obtain the dismissal,
----------------------
within sixty (60) days after the commencement thereof, of any bankruptcy,
reorganization or insolvency proceeding, or other proceeding under any law for
the relief of debtors, instituted against Tenant by one or more third parties or
any partner of Tenant, or, in any such proceeding, defaults or files an answer
admitting the material allegations upon which the proceeding was based or
alleges its willingness to have an order for relief entered or its desire to
seek liquidation, reorganization or adjustment of any of its debts;
-37-
25.1.7 Receivership. Any receiver, trustee or custodian is appointed
------------
to take possession of all or any substantial portion of the assets of Tenant, or
of Tenant's interest in this Lease;
25.1.8 Liens. Tenant fails to cause the release, within twenty (20)
-----
days after filing, of any lien arising out of any work performed, materials
furnished, or obligations incurred by or for Tenant, which has been filed
against the Premises;
25.1.9 Assignment. Tenant attempts a transfer, conveyance, mortgage,
----------
encumbrance, pledge, disposition, assignment, sublease or other act in
contravention of Article 15 hereof and fails to cure the same within two (2)
business days of receipt of written notice from Landlord;
25.1.10 Insurance. Tenant fails to maintain in full force and effect
---------
the insurance coverages required to be maintained by Tenant under this Lease
following written notice thereof from Landlord to Tenant and Tenant's failure to
cure the same within five (5) business days of receipt of such notice; or
25.1.11 Default Under Xxxxxxx Lease. The occurrence of an "Event of
---------------------------
Default" (as defined in the Xxxxxxx Lease) under the Xxxxxxx Lease shall
constitute an immediate and noncurable Event of Default under this Lease.
25.2 Remedies of Landlord. In the event of any such Event of Default by
--------------------
Tenant, Landlord may at any time thereafter, at Landlord's option and without
limiting the exercise of any other right or remedy which Landlord may have in
law or equity by reason of such default or breach, with or without notice or
demand, do any of the following:
25.2.1 Regain Possession. Re-enter the Premises and take possession
-----------------
of the same and of all equipment, fixtures and personal property of Tenant
therein, expel or remove Tenant and all other parties occupying the Premises,
using such force as may be reasonably necessary to do so, without being liable
to any prosecution for such re-entry or for the use of such force, and without
terminating this Lease, and at any time (and from time to time) relet the
Premises or any part thereof for the account of Tenant for such term and upon
such conditions and at such rental as Landlord may deem proper in its sole
discretion. In such event Landlord may receive and collect the rent from such
reletting and apply it first against any and all expenses and costs incurred by
Landlord hereunder as a result of Landlord having to retake and relet the
Premises (including, without limitation, such expenses as Landlord may have
incurred in recovering possession of the Premises, placing the same in good
order and condition, altering, repairing or redecorating the same for reletting
and all other reasonable expenses, commissions and charges, including attorneys'
fees, which Landlord may have paid or incurred in connection with such
repossession and reletting) and then the balance, if any, shall be applied
against any Rent then due from Tenant to Landlord. Landlord may execute any
lease made pursuant hereto in Landlord's name and the tenant thereunder shall be
under no obligation to see to the application by Landlord of any rent collected
by Landlord, nor shall Tenant have any right to collect any rent thereunder.
Whether or not the Premises are relet, Tenant shall pay Landlord all amounts
required to be paid by Tenant up to the date of Landlord's re-entry and
thereafter Tenant shall pay Landlord, until the end of the Term, the amount of
all rent and other charges required to be
-38-
paid by Tenant hereunder, less the proceeds of such reletting during the Term,
if any, after payment of Landlord's expenses as provided above. Such payments by
Tenant shall be due at such times as are provided in this Lease, and Landlord
need not wait until the termination of this Lease to recover them by legal
action or otherwise. Landlord shall not by any re-entry or other act be deemed
to have terminated this Lease or the liability of Tenant for the total Rent due
hereunder unless Landlord shall give Tenant written notice of Landlord's
election to terminate this Lease.
25.2.2 Termination. Give written notice to Tenant of Landlord's
-----------
election to terminate this Lease at any time after an Event of Default, re-enter
the Premises and take possession of the same and of all equipment, fixtures and
personal property therein, and expel or remove Tenant and all other parties
occupying the Premises, using such force as may be reasonably necessary to do
so, without being liable to any prosecution for such re-entry or for the use of
such force. In such event Landlord shall thereupon be entitled to recover from
Tenant as damages, all of the following:
i. The worth at the time of award of any unpaid Rent which
had been earned at the time of such termination; plus
ii. The worth at the time of award of the amount by which the
unpaid Rent which would have been earned after termination until the time of
award exceeds the amount of such rent loss that Tenant proves could have been
reasonably avoided; plus
iii. The worth at the time of award of the amount by which the
unpaid Rent for the balance of the Term after the time of the award exceeds the
amount of such Rent loss that Tenant proves could have been reasonably avoided;
plus
iv. Any other amount necessary to compensate Landlord for all
the detriment proximately caused by Tenant's failure to perform its obligations
under this Lease or which in the ordinary course of things would be likely to
result therefrom, including, but not limited to any costs or expenses incurred
by Landlord in retaking possession of the Premises, including reasonable
attorneys' fees; maintaining or preserving the Premises after such Event of
Default; preparing the Premises for reletting to a new tenant, including repairs
or alterations to the Premises for such reletting; leasing commissions; or any
other costs necessary or appropriate to relet the Premises; plus
v. At Landlord's election, such other amounts in addition to
or in lieu of the foregoing as may be permitted from time to time by the laws of
the State of California.
vi. As used in subsections (i) and (ii) above, the "worth at
the time of award" is computed by allowing interest at the rate set forth in
Article 34 below. As used in subsection (iii) above, the "worth at the time of
award" is computed by discounting such amount at the discount rate of the
Federal Reserve Bank of San Francisco at the time of award plus one percent
(1%).
25.2.3 Tenant's Property. Landlord may at its option permit all of
-----------------
Tenant's fixtures, furniture, equipment, improvements, additions, alterations,
and other personal property to remain on the Premises and in that event, and
continuing during the length of said Event of
-39-
Default, Landlord shall have the right to take exclusive possession of the same
and to use the same, free of charge, until all Events of Default are cured or,
at its option, at any time during the Term, to require Tenant to forthwith
remove the same. In the alternative, in the event of any entry or taking
possession of the Premises as aforesaid, Landlord shall have the right, but not
the obligation, to remove therefrom all or any part of the personal property
located therein and may place the same in a public warehouse at the expense and
risk of the owner or owners thereof and dispose of the same in accordance with
the provisions of California Civil Code Section 1980 et seq. or any successor
statutes thereto.
25.2.4 Cure of Default. In addition to the foregoing remedies,
---------------
Landlord shall, so long as this Lease is not terminated, have the right to
remedy any Event of Default, to maintain or improve the Premises without
terminating this Lease, to incur reasonable expenses on behalf of Tenant in
seeking a subtenant, or to cause a receiver to be appointed to administer the
Premises and any new or existing subleases, and Tenant shall pay to Landlord as
Additional Rent hereunder all of Landlord's reasonable costs in so doing, with
interest at the maximum lawful rate.
25.2.5 Cumulative Remedies. No remedy or election hereunder shall be
-------------------
deemed exclusive but shall, wherever possible, be cumulative with all other
remedies at law or in equity.
25.3 Default by Landlord. Landlord shall not be deemed to be in default or
-------------------
breach in the performance of any obligation required to be performed by Landlord
under this Lease unless and until it has failed to perform such obligation
within thirty (30) days after written notice by Tenant to Landlord specifying
that Landlord has failed to perform such obligation; provided, however that if
the nature of Landlord's obligation is such that more than thirty (30) days are
required for its performance, then Landlord shall not be deemed to be in default
or breach if it shall commence such performance within such thirty (30) day
period and thereafter diligently prosecute the same to completion. Tenant shall
have no right to terminate this Lease, except where Landlord fails to cure a
material breach within the time periods set forth in the immediately preceding
sentence. No default or breach on the part of Landlord that would entitle Tenant
under the terms of this Lease or by law to terminate this Lease shall result in
a termination of this Lease unless (i) Tenant has given written notice of such
default or breach by registered or certified mail to any beneficiary of a deed
of trust or mortgagee of a mortgage covering the Premises whose address shall
have been furnished to Tenant and (ii) Tenant offers such beneficiary or
mortgagee the same opportunity to cure the default or breach as is available to
Landlord under the express terms of this Lease. It is expressly understood and
agreed that any money judgment against Landlord resulting from any default or
other claim arising under this Lease or related thereto shall be satisfied only
out of Landlord's equity interest in the Premises, and no other real, personal
or mixed property of Landlord, wherever situated, shall be subject to levy on
any such judgment obtained against Landlord and if such equity interest in the
Premises is insufficient for the payment of such judgment, Tenant will not
institute any further action, suit, claim or demand, in law or in equity,
against Landlord for the amount of such deficiency. Tenant hereby waives, to the
extent waivable under law, any right to satisfy said money judgment against
Landlord except from Landlord's equity interest in the Premises.
-40-
ARTICLE 26
HOLD OVER
---------
If Tenant holds over after the expiration or earlier termination of
the Term or any Extended Term of this Lease without the express prior written
consent of Landlord, Tenant shall become a tenant of sufferance only at a rental
rate equal to one hundred fifty percent (150%) of the Monthly Base Rent in
effect just prior to expiration or termination, and otherwise upon the terms,
covenants and conditions herein specified, so far as applicable. Acceptance by
Landlord of any Rent after such expiration or earlier termination shall not
constitute a consent to a holdover hereunder or result in a renewal of the Lease
or any lease. The foregoing provisions of this Article 26 are in addition to and
do not affect Landlord's right of reentry or any other rights of Landlord
hereunder or as otherwise provided by law or equity.
ARTICLE 27
CONDITION OF PREMISES
---------------------
Tenant acknowledges that, except as expressly set forth in this Lease,
neither Landlord nor any agent of Landlord has made any representation or
warranty with respect to the Premises, Landlord's prior use of the Premises, the
presence of any Hazardous Materials in the Premises, the adequacy or inadequacy
of parking for Tenant's intended office use of the Premises, the compliance of
the Premises with any applicable statutes, laws, ordinances or regulations
(including, without limitation, any Environmental Laws), or with respect to the
suitability of any part of the Premises for the conduct of Tenant's business.
ARTICLE 28
QUIET POSSESSION
----------------
Upon Tenant's paying the Rent reserved hereunder and observing and
performing all of the covenants, conditions and provisions on Tenant's part to
be observed and performed hereunder, Tenant shall have peaceful and quiet
possession of the Premises for the entire Term and any Extended Term(s) hereof,
subject to all of the terms and conditions of this Lease.
ARTICLE 29
DAMAGE TO TENANT'S PROPERTY
---------------------------
Landlord and its agents shall not be liable for any damage to Tenant's
property entrusted to employees of Landlord or its agents, nor for loss or
damage to any property by theft or otherwise. Landlord or its agents shall not
be liable for interference with the light or other incorporeal hereditaments.
-41-
ARTICLE 30
CONFLICT OF LAWS
----------------
This Lease shall be governed by and construed pursuant to the laws of
the State of California.
ARTICLE 31
SUCCESSORS AND ASSIGNS
----------------------
Except as otherwise provided in this Lease, all of the covenants,
conditions and provisions of this Lease shall be binding upon and shall inure to
the benefit of the parties hereto and their respective heirs, personal
representatives, successors and assigns. Any options or rights given to the
Tenant in this Lease to extend or renew this Lease shall be personal to the
original Tenant named herein and to any Tenant Affiliate to whom this Lease may
be assigned and may not be transferred to any other successor or assign
(including, without limitation, any Tenant Subsidiary) without the prior written
consent of Landlord.
ARTICLE 32
BROKERS
-------
Tenant warrants that it has had no dealings with any real estate
broker, leasing agent or finder in connection with this Lease, excepting only
the brokers named in Items 14 and 15 of the Basic Lease Provisions and that it
knows of no other real estate broker, leasing agent or finder other than the
brokers named in Items 14 and 15 of the Basic Lease Provisions who is entitled
to a commission in connection with this Lease. Tenant agrees to pay and to
indemnify and hold Landlord harmless from, any cost, expense or liability for
any compensation, commission or charges claimed by any other realtors, brokers,
agents or finders claiming by, through or on behalf of Tenant with respect to
this Lease and/or the negotiation thereof. Landlord warrants that it has had no
dealings with any real estate broker, leasing agent or finder in connection with
this Lease, excepting only the brokers named in Items 14 and 15 of the Basic
Lease Provisions and that it knows of no other real estate broker, leasing agent
or finder other than the brokers named in Items 14 and 15 of the Basic Lease
Provisions who is entitled to a commission in connection with this Lease.
Landlord agrees to pay and to indemnify and hold Tenant harmless from, any cost,
expense or liability for any compensation, commission or charges claimed by any
other realtors, brokers, agents or finders claiming by, through or on behalf of
Landlord with respect to this Lease and/or the negotiation thereof. Landlord
covenants and agrees to pay in accordance with its agreement with the broker
named in Item 14, all real estate commissions due in connection with this Lease
to such broker.
-42-
ARTICLE 33
NEGOTIATED AGREEMENT
--------------------
Tenant and Landlord have been represented by independent counsel in
entering into this Lease. Each of the parties affirms to the other that it has
consulted and discussed the provisions of this Lease with its counsel and fully
understands the legal effect of each provision. The drafting and negotiation of
this Lease has been participated in by each of the parties. For all purposes,
this Lease shall be deemed to have been drafted jointly by each of the parties
and shall not be construed against any party due to authorship.
ARTICLE 34
INTEREST ON TENANTS OBLIGATIONS; LATE CHARGE
--------------------------------------------
34.1 Interest. Any amount due from Tenant to Landlord which is not paid
--------
within three (3) business days of its due date shall bear interest at the lesser
of (i) twelve percent (12%) per annum or (ii) the maximum rate permitted by law
from the date such payment is due (after the expiration of any applicable cure
period hereunder, if any) until paid, but the payment of such interest shall not
excuse or cure any default or breach by Tenant.
34.2 Late Charges. Tenant recognizes that late payment of any Rent or any
------------
portion thereof will result in administrative expense to Landlord, the extent of
which additional expense is extremely difficult and economically impractical to
ascertain. Tenant therefore agrees that if Rent or any portion thereof, remains
unpaid ten (10) business days after said amount is due and written notice from
Landlord demanding payment, the amount of such unpaid Rent shall be increased by
a late charge to be paid Landlord by Tenant equal to five percent (5%) of the
amount of the delinquent Rent or other payment. The amount of the late charge to
be paid Landlord by Tenant on any unpaid Rent or other unpaid amount shall be
due immediately after the date on which the late charge was initially imposed.
Tenant agrees that such late charge is a reasonable estimate of the loss and
expense to be suffered by Landlord as a result of such late payments by Tenant
and may be charged by Landlord to defray such loss and expense. The provisions
of this Section in no way relieve Tenant of the obligation to pay Rent or other
amounts on or before the date on which they are due, nor do the terms of this
Section in any way affect Landlord or its obligations under this Lease or
obligate Landlord to accept less than the full Rent amount due at any time.
ARTICLE 35
TIME
----
Time is of the essence of this Lease and the performance of any and
all of its provisions.
-43-
ARTICLE 36
DEFINED TERMS AND MARGINAL HEADINGS
-----------------------------------
The words "Landlord" and "Tenant" as used herein shall include the
plural as well as the singular. If more than one person is named as Tenant the
obligations of such persons are joint and several. The captions or marginal
headings to the Articles and Sections of this Lease are not a part of this Lease
and shall have no effect upon the construction or interpretation of any part
hereof.
ARTICLE 37
PRIOR AGREEMENTS
----------------
This Lease and its Exhibits contain all of the agreements of the
parties hereto with respect to any matter covered or mentioned in this Lease,
and no prior agreement, understanding, representation, correspondence
(including, without limitation, that certain letter of intent between the
parties dated June 14, 1999 and that certain Office Lease dated July 30, 1999
covering both the Premises and the Xxxxxxx Premises, which Office Lease the
parties acknowledge and agree shall be null and void and of no further force or
effect upon the execution and delivery of this Lease and the Xxxxxxx Lease by
the parties hereto), or communication pertaining to any such matter or the
Premises shall be effective for any purpose. No provision of this Lease may be
amended, supplemented or modified except by an agreement in writing signed by
the parties hereto or their respective successors in interest. If any provision
of this Lease shall be held invalid, void or unenforceable to any extent, the
remainder of this Lease shall not be affected thereby and each provision of this
Lease shall be valid and enforceable to the fullest extent permitted by law.
ARTICLE 38
AUTHORITY OF PARTIES
--------------------
Tenant does hereby covenant, represent and warrant that (i) Tenant is
a duly authorized and existing corporation; (ii) Tenant is qualified to do
business in the State of California and is in good standing in the jurisdiction
of its formation; (iii) Tenant has full right and authority to enter into this
Lease; (iv) each person signing on behalf of the corporation was authorized to
do so; and (v) the Lease is valid and legally binding on Tenant. Landlord does
hereby covenant, represent and warrant that (i) Landlord is duly authorized and
existing corporation; (ii) Landlord is qualified to do business in the State of
California and is in good standing in the jurisdiction of its formation; (iii)
Landlord has full right and authority to enter into this Lease; (iv) each person
signing on behalf of the corporation was authorized to do so; and (v) the Lease
is valid and legally binding on Landlord.
-44-
ARTICLE 39
NO LIGHT, AIR OR VIEW EASEMENT
------------------------------
Any diminution or shutting off of light, air or view by any structure
which may be erected on lands adjacent to or in the vicinity of the Premises
shall in no way affect this Lease, impose any liability on Landlord, or permit
Tenant to reduce, setoff or xxxxx rent or seek any other remedies or relief.
ARTICLE 40
EXAMINATION OF LEASE
--------------------
Submission of this instrument for examination or signature by Tenant
does not constitute a reservation of or option for lease, and it is not
effective as a lease or otherwise legally binding until execution by and
delivery to both Landlord and Tenant.
ARTICLE 41
FORCE MAJEURE
-------------
Any covenants, conditions, provisions or agreements on the part of one
party to perform any act or thing for the benefit of the other shall not be
deemed breached if such party is unable to furnish or perform the same by virtue
of a strike, lock out, fire, earthquake, explosion, riot, material or supply
shortages, Acts of God, laws, roles, orders, ordinances, directions, regulations
or requirements of any federal, state, county or municipal authority, labor
dispute or any other cause whatsoever beyond such party's reasonable control;
provided, however, that nothing in this Article 41 shall be deemed to relieve
either party from paying the other any sums owed to the other party under this
Lease (including, in the case of Tenant, any Rent) when such sums are due.
Unless expressly provided in this Lease, Tenant's Rent shall not be abated by
reason of such inability on the part of Landlord.
ARTICLE 42
RECORDING
---------
Tenant shall not record this Lease nor any form of memorandum hereof
without the prior written consent of Landlord, which consent may be withheld or
conditioned in Landlord's sole and absolute discretion. Any recording of this
Lease or any memorandum hereof without the prior written consent of Landlord
shall constitute a default by Tenant under this Lease. Landlord, in its sole and
absolute discretion, may record this Lease or a memorandum hereof.
-45-
ARTICLE 43
INCORPORATION BY REFERENCE
--------------------------
The Basic Lease Provisions, Addenda (if any) and Exhibits attached
hereto all constitute parts of this Lease and any reference thereto incorporates
such matters in this Lease as if the same were fully set forth herein.
ARTICLE 44
DEFINITION OF ADDITIONAL RENT
-----------------------------
The Monthly Base Rent, Property Taxes, insurance premiums, maintenance
and repair costs incurred by Landlord under Article 6 above, and all other
amounts required to be paid by Tenant hereunder ("Additional Rent") including,
without limitation, interest, late charges, advance rent and reimbursements, are
sometimes collectively referred to in this Lease as, and shall constitute "Rent"
or "rent". Demand for payment of Rent shall not constitute a forbearance and
shall not compromise Landlord's right to deem Tenant's failure to pay such Rent
in a timely manner as a default or limit any other rights given to Landlord
under this Lease or by law or equity.
ARTICLE 45
SURRENDER OF PREMISES
---------------------
On the Expiration Date or the earlier termination of the Lease, Tenant
shall surrender the Premises and every part and system thereof to Landlord broom
clean and in as good condition as delivered to Tenant, reasonable wear and tear,
condemnation and casualty excepted, and free of all debris and Hazardous
Materials placed on the Premises by Tenant or Tenant Parties and in full
compliance with all requirements of Section 9.6 above. Unless Landlord has
required removal pursuant to Section 7.3 above, Tenant's initial Tenant
Improvements made by or for Tenant render the Work Letter and all other
improvements, alterations and additions made by or for Tenant to the Premises in
accordance with Section 7.3 of the Lease, shall become part of the Premises on
the Expiration Date or earlier termination of this Lease and be surrendered,
together with the Premises, to Landlord in good, serviceable and operating
condition, reasonable wear and tear, condemnation and casualty excepted. Tenant
shall remove all of its trade fixtures, equipment and personal property and
signs, provided such removal will not adversely affect the structural integrity
of the Premises. Any property not so removed within ten (10) days after the
Expiration Date or earlier termination of the Lease shall be deemed abandoned by
Tenant and shall become Landlord's property which Landlord may use, remove, or
dispose of in accordance with California Civil Code Section 1980 et seq. or any
successor statutes thereto. Tenant shall reimburse Landlord for any cost
incurred by Landlord in such removal, storage or disposition, or in repairing or
restoring the Premises. Tenant shall further defend and indemnify Landlord
against all claims, losses, costs, expenses, actions, judgments, damages and
liabilities resulting from Tenant's failure and delay in surrendering the
Premises as above provided including, without limitation, any claim made by any
succeeding tenant of the Premises resulting from or related to such failure to
surrender, which
-46-
indemnification and defense obligations shall survive the expiration or earlier
termination of this Lease.
ARTICLE 46
NO ACCORD AND SATISFACTION
--------------------------
No payment by Tenant or receipt by Landlord of a lesser amount than
due shall be deemed to be other than on account of the full amount due and
Landlord may accept such check or payment without prejudice to Landlord's rights
to recover the balance.
ARTICLE 47
MERGER
------
The voluntary or other surrender of this Lease by Tenant, or a mutual
cancellation thereof, or a termination by Landlord, shall not work as a merger,
and shall, at the option of Landlord, terminate all or any existing subtenancies
or may, at the option of Landlord, operate as an assignment to Landlord of any
or all of such subtenancies.
ARTICLE 48
FINANCIAL STATEMENTS
--------------------
The Financial Statements of Tenant were submitted as an inducement and
consideration to Landlord to enter into this Lease. Tenant represents and
warrants to Tenant that the Financial Statements were true and correct as of the
date thereof. Tenant further represents
-47-
and warrants to Landlord that to Tenant's actual knowledge there have been no
material adverse changes in the financial condition of Tenant since the date of
the Financial Statements.
IN WITNESS WHEREOF, the parties hereto have executed this Lease,
consisting of the foregoing Basic Lease Provisions and Articles 1 through 48,
together with Exhibits A through E, all of which are incorporated herein in
--------------------
their entirety by this reference, as of the date set forth above.
LANDLORD: TENANT:
ALZA CORPORATION, a Delaware CHEMDEX CORPORATION, a Delaware
corporation corporation
By: /s/ Xxxxxx Xxxxx By: /s/ Xxxxx X. Xxxxxxx
------------------------------------- ----------------------------
Xxxxxx Xxxxx
Its: Sr. Vice Pres., Human Resources Its: Xxxxx X. Xxxxxxx
------------------------------------ ---------------------------
Chief Financial Officer
By: /s/ Xxxxx Staple By: /s/ Xxxxx X. Xxxxx
------------------------------------- ----------------------------
Xxxxx Staple
Its: Sr. Vice President & Gen. Counsel Its: Xxxxx X. Xxxxx
------------------------------------ ---------------------------
President & CEO
-48-
EXHIBIT A
---------
DESCRIPTION OF REAL PROPERTY
----------------------------
All that certain real property situated in the City of Mountain View,
County of Santa Xxxxx, State of California, described as follows:
PARCEL ONE:
----------
The Southerly 0.471 acres as shown upon that certain Record of Survey filed
for record in the office of the Recorder of the County of Santa Xxxxx,
State of California, on October 3, 1959 in Book 83 of Maps at Page 14.
PARCEL TWO:
----------
Portion of Lot 39, as shown upon that certain Map entitled, "MAP OF LOS
ALAMOS ACRES", which Map was filed for record in the office of the Recorder
of the County of Santa Xxxxx, State of California on March 19, 1929 in Book
"X" of Maps, at Pages 28 and 29, and more particularly described as
follows:
BEGINNING at a point in the centerline of Xxxxxxx Road, distant thereon
268.9 feet Northerly from the point of intersection of said centerline of
Xxxxxxx Road, with the centerline of Plymouth Street, as said Road and
Street are shown on the Map above referred to; running thence Northerly
along the centerline of Xxxxxxx Road, 100 feet to the Northeasterly corner
of Lot 39, as said Lot is shown on the Map above referred to; running
thence Westerly along the Northerly line of said Lot 39, 118.3 feet to the
Northwesterly corner thereof; running thence Southerly along the Westerly
line of said Lot 39, 100 feet; running thence Easterly and parallel with
the said centerline of Plymouth Street, 118.03 feet to the point of
beginning.
PARCEL THREE:
------------
Portion of Lot 39, as shown upon that certain Map entitled, "MAP OF LOS
ALAMOS ACRES", which Map was filed for record in the Office of the Recorder
of the County of Santa Xxxxx, State of California, on March 19, 1929 in
Book X of Maps, at Pages 28 and 29, and more particularly described as
follows:
BEGINNING at the point of intersection of the center line of Xxxxxxx Xxxx,
00 feet wide, with the center line of Xxxxxxxx Xxxxxx, 00 feet wide, as
said road and street are shown upon the Map hereinabove referred to; thence
North along said center line of Xxxxxxx Road, 268.9 feet to the
Southeasterly corner of the Parcel of land conveyed by Xxxxxxx X. Xxxxxx,
et ux, to Xxxxxxxx Xxxx, et ux, by Deed dated April 13, 1946 and recorded
August 20, 1946 in Book 1363 Official Records, Page 324, Santa Xxxxx County
Records; thence along the Southerly line of said Parcel of land and
parallel with said center line of Xxxxxxxx Xxxxxx, Xxxxx 00 degrees 01'
West 118.3 feet to the Westerly line of Lot 39, as shown on said Map;
thence South along said Westerly line of Lot 39, 268.9 feet to said center
line of Plymouth Street; thence along said last mentioned line, South 86
degrees 01' East 118.03 feet to the point of beginning.
PARCEL FOUR:
-----------
All of Lot 38, as shown on that certain Map entitled, "MAP OF LOS ALAMOS
ACRES", which Map was filed for record in the office of the Recorder of the
County of Santa Xxxxx, State of California, on March 19, 1929, in Book X of
Maps at Pages 28 and 29.
PARCEL FIVE:
-----------
All of Lot 37, as shown on that certain Map entitled, "MAP OF LOS ALAMOS
ACRES", which Map was filed for record in the office of the Recorder of the
County of Santa Xxxxx, State of California, on March 19, 1929, in Book X of
Maps at Pages 28 and 29.
-1-
EXHIBIT B
---------
Lease Period Monthly Base Rent
Original Lease Term
-------------------
Commencement Date to 10/14/00 $228,000 (subject to free rent per (S) 3.2)
10/15/00 to 10/14/01 $234,840
10/15/01 to 10/14/02 $241,885
10/15/02 to 10/14/03 $249,142
10/15/03 to 10/14/04 $256,616
10/15/04 to 02/28/05 $264,314
Extended Terms
--------------
03/01/05 to 10/14/05 $264,314
10/15/05 to 10/14/06 $272,244
10/15/06 to 02/28/07 $280,411
-1-
EXHIBIT C
---------
FORM OF LETTER OF CREDIT
XXXXX FARGO BANK, N.A.
TRADE SERVICES DIVISION, NORTHERN CALIFORNIA
000 XXXXXX XXXXXX, 00XX XXXXX
XXX XXXXXXXXX, XXXXXXXXXX 00000
IRREVOCABLE LETTER OF CREDIT
ALZA Corporation Letter of Credit No. NZS ________
000 Xxxx Xxxx Xxxx Date: _________ __, 1999
Xxxx Xxxx, XX 00000
Attention: Senior Vice President & General Counsel
Ladies and Gentlemen:
At the request and for the account of Chemdex Corporation, 0000 Xxxxxx Xxx,
Xxxx Xxxx, XX 00000, we hereby establish our Irrevocable Letter of Credit in
your favor in the amount of Xxx Xxxxxxx Xxxxx Xxxxxxx Xxxxxxx-Xxxx Xxxxxxxx
Xxxxxx Xxxxxx Dollars (US$1,875,000) available with us at our above office by
payment of your draft(s) drawn on us at sight in the form of Exhibit 1 hereto
with the instructions in brackets therein complied with accompanied by your
signed and dated statement in the form of Exhibit 2 hereto with the instructions
in brackets therein complied with.
Each drawing must also be accompanied by the original of this Letter of
Credit for our endorsement on this Letter of Credit of our payment of such
drawing.
Partial and multiple drawings are permitted under this Letter of Credit,
however each drawing must be in an amount of not less than US$20,000.00.
If any instructions accompanying a drawing under this Letter of Credit
request the payment is to be made by transfer to an account with us or at
another bank, we and/or such other bank may rely on an account number specified
in such instructions even if the number identifies a person or entity different
from the intended payee.
This Letter of Credit expires at our above office on July 31, 2000, but
shall be automatically extended, without written amendment, to July 31 in each
succeeding calendar year up to, but not beyond, April 30, 2005 unless we have
sent written notice to you at your address above by registered mail or express
courier that we elect not to renew this Letter of Credit beyond the date
specified in such notice (the "Non-Renewal Expiration Date"), which Non-Renewal
Expiration Date will be July 31, 2000 or any subsequent July 31 occurring before
April 30, 2005 and be at least 60 calendar days after the date we send you such
notice.
-1-
This Letter of Credit is transferable one or more times, but in each
instance to a single transferee and only in the full amount available to be
drawn under this Letter of Credit at the time of such transfer. Any such
transfer may be effected only through ourselves and only upon presentation to us
at our above-specified office of a duly executed instrument of transfer in the
form attached hereto as Exhibit 3 with the instructions in brackets therein
complied with together with the original of this Letter of Credit. Any transfer
of this Letter of Credit may not change the place of expiration of this Letter
of Credit from our above-specified office. Each transfer shall be evidenced by
our endorsement on the reverse of the original of this Letter of Credit, and we
shall deliver the original of this Letter of Credit so endorsed to the
transferee. All commissions and charges in connection with this transfer are for
the account of Chemdex Corporation.
This Letter of Credit is subject to the Uniform Customs and Practice for
Documentary Credits (1993 revision), International Chamber of Commerce
Publication No. 500, and engages us in accordance therewith.
Very truly yours,
XXXXX FARGO BANK, N.A.
BY:
------------------------
(AUTHORIZED SIGNATURE)
-2-
Exhibit 1
Xxxxx Fargo Bank, N.A
Letter of Credit No. __________
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx
Xxx Xxxxxxxxx, XX 00000
Attention: Manager, Standby Letter of Credit Dept.
DRAFT
Date of Draft: [insert date]
To the order of [insert Beneficiary Name], pay [insert amount of
drawing in words]
UNITED STATES DOLLARS (U.S. $ [insert amount of drawing in numbers]) at
sight
For value received under Letter of Credit No. __________
"Drawn under Xxxxx Fargo Bank, N.A. Letter of Credit No. __________
dated August __,1999."
[insert Beneficiary Name]
By: [insert signature]
Its: [insert title]
-3-
Exhibit 2
Xxxxx Fargo Bank, N.A
Letter of Credit No. __________
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx
Xxx Xxxxxxxxx, XX 00000
Attention: Manager, Standby Letter of Credit Dept.
Re: Letter of Credit No. __________
Ladies and Gentlemen:
1. The undersigned Beneficiary, [insert Beneficiary Name], is Landlord
under that certain Office Lease dated August __, 1999 ("Lease") with Chemdex
Corporation, a Delaware corporation, as Tenant.
2. The undersigned Beneficiary is entitled to payment under the Lease in
the amount of U.S.$[insert amount of draft which accompanies this statement]
(the "Draw Amount") in accordance with the applicable provisions of the Lease
(as the same may have been amended to date), which is the same amount as the
Draft accompanying this Certificate and is less than or equal to the amount
currently available under the Letter of Credit.
3. The individual executing this Certificate on behalf of Beneficiary is a
duly authorized officer of Beneficiary.
Date: [insert date] [insert Beneficiary Name]
By: [insert signature]
Its: [insert title]
-4-
Exhibit 3
Xxxxx Fargo Bank, N.A
Letter of Credit No. __________
Date: [insert date]
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx, 00xx Xxxxx
Xxx Xxxxxxxxx, Xxxxxxxxxx 00000
Attention: Manager, Standby Letter of Credit Department
Subject: Your Letter of Credit No. __________
Ladies and Gentlemen:
For value received, we hereby irrevocably assign and transfer all our
rights under the above-captioned Letter of Credit, as heretofore and hereafter
amended, extended or increased, to:
______________________________
[ insert Name of Transferee]
______________________________
______________________________
[ insert Address of Transferee]
By this transfer, all of our rights in the Letter of Credit are transferred
to the transferee, and the transferee shall have sole rights as beneficiary
under the Letter of Credit, including sole rights relating to any amendments,
whether increases or extensions or other amendments, and whether now existing or
hereafter made. You are hereby irrevocably instructed to advise furore
amendment(s) of the Letter of Credit to the transferee without our consent or
notice to us.
You are hereby advised that [ insert Name of Transferee] succeeded to all
of beneficiary's right, title and interest under that certain Office Lease dated
August __, 1999 (as the same may have been amended to date), with Chemdex
Corporation, a Delaware corporation, as Tenant.
Enclosed are the original Letter of Credit and the original of all
amendments to this date. Please notify the transferee of this Transfer and of
the terms and conditions of the Letter of
-5-
Credit as transferred. All fees and charges in connection with this Transfer are
for the account of Chemdex Corporation.
Very truly yours,
[Insert Name of Beneficiary]
By: [insert signature]
Its:[insert title]
Signature of Transferor Guaranteed
[Insert Name of Bank]
By: [insert signature]
Name: [insert typed or printed name]
Title: [insert title]
-6-
EXHIBIT D
---------
WORK LETTER FOR TENANT IMPROVEMENTS
1. Delivery of Possession. Landlord shall deliver possession of the
----------------------
Premises to Tenant in "AS-IS" and "WITH ALL FAULTS" condition on the
Commencement Date (as defined in Section 2.1 of the Lease) to permit Tenant and
the Contractor Group (defined below) to commence and diligently pursue to
completion the Tenant Improvements (defined below) within the Premises. Tenant
acknowledges that Landlord has no obligation whatsoever to alter, repair,
restore, upgrade or improve the Premises under this Work Letter for Tenant
Improvements ("Work Letter"). As used herein, "Contractor Group" shall mean the
General Contractor (defined below) and each of its subcontractors, sub-
subcontractors, laborers, materialmen and suppliers providing labor or materials
to the Tenant Improvements. Capitalized terms used in this Work Letter and not
defined herein shall have the meanings given them in the Lease.
2. Tenant Improvements. Tenant, at its sole cost and expense, shall
-------------------
construct and install within the Premises its desired tenant improvements and
other improvements in accordance with the Approved Working Drawings (defined
below), which tenant improvements may include, without limitation, (i)
demolition of certain limited existing interior walls and other improvements
within the Premises, (ii) construction, installation and/or reconfiguration of
certain ceilings, interior walls and partitions, interior finishing of exterior
walls (including, without limitation, the plastering, furring, drywalling,
taping and/or other finishing of such walls), interior doors, floor coverings
and the preparation of all floors for same, cabinetry and millwork, restrooms,
light fixtures, wall coverings and other improvements, finishings and painting
within the Premises, (iii) modifications to floors for above-normal floor
loading requirements of Tenant, (iv) modifications reasonably required by Tenant
to the heating, ventilating and air conditioning ("HVAC") systems, ducts and
means of distribution for the same within the Premises, (v) improvements,
additions, alterations and fixtures within the buildings on the Premises
necessary for all Tenant Improvements and all portions of all buildings affected
by the Tenant Improvements to comply with all applicable codes, statutes, rules,
regulations, ordinances and orders of any federal, state, county or municipal
agency having jurisdiction over the Premises including all local, state and
federal requirements for disability access including, without limitation, the
Americans With Disabilities Act, 42 U.S.C. Section 1201 et seq. and California
Government Code Section 4450 et seq. (collectively, "ADA"), (vi) all telephone,
telecommunication, computer and data systems, switch room, cabling, lines,
conduit, receptacles, switches and related equipment and improvements running
from point of entry in the Premises, and (vii) all other necessary, desirable or
required improvements, alterations, fixtures and finishes which are to be
installed within or incorporated into the Premises by Tenant (collectively, the
"Tenant Improvements"). Tenant shall commence to construct and install the
Tenant Improvements at Tenant's sole cost and expense promptly from and after
Commencement Date and diligently pursue to completion, subject to Force Majeure
delays, the construction of all Tenant Improvements.
-1-
3. Working Drawings.
----------------
3.1 Selection of Architect and Engineer; Working Drawings. Tenant
-----------------------------------------------------
shall retain a reputable architect (the "Architect") to the extent required by
Landlord and as approved by Landlord, which approval shall not be unreasonably
withheld or delayed, to prepare the "Working Drawings", as that term is defined
in this Section 3.1. No Working Drawings shall be required for carpeting,
painting and other di minimus improvements within the Premises. If necessary to
construct or install the Tenant Improvements, Tenant shall also retain an
engineering design build contractor (the "Engineer") approved by Landlord, which
approval shall not be unreasonably withheld or delayed, to prepare all plans and
engineering working drawings relating to any HVAC work or reconfiguration to be
performed by or for Tenant in the Premises. If Landlord fails to disapprove
Tenant's proposed Architect or Engineer in writing to Tenant, as the case may
be, within five (5) business days after receipt of written notice from Tenant
identifying the same, then Landlord shall be deemed to have approved Tenant's
proposed Architect or Engineer, as the case may be. The plans and drawings to be
prepared by Architect and the Engineer (if any) hereunder are collectively
referred to herein as the "Working Drawings." All Working Drawings shall be
subject to Landlord's approval, which approval shall not be unreasonably
withheld or delayed. Landlord shall advise Tenant within ten (10) business days
after Landlord's receipt of the proposed Working Drawings if the Working
Drawings are unsatisfactory, with a reasonable description of any matters found
to be not acceptable to Landlord. If Landlord fails to return Tenant's proposed
Working Drawings to Tenant marked "Approved", "Approved as Noted" or
"Disapproved" within said ten (10) business-day period, then Landlord shall be
deemed to have approved Tenant's proposed Working Drawings. Tenant's Working
Drawings, as finally revised and marked or deemed approved by Landlord, shall be
initialed by Landlord and Tenant and shall be referred to as the "Approved
Working Drawings". If Approved Working Drawings are not agreed upon within five
(5) business days after delivery to Tenant of "Disapproved" Working Drawings or
"Approved as Noted" Working Drawings, then Landlord or Tenant may submit the
disputed items to an arbitration panel consisting of Landlord's architect, an
architect appointed by Tenant (who may be the Architect who prepared Tenant's
Working Drawings), and a third architect appointed by said architects. Tenant
shall appoint its architect within five (5) business days after written notice
from Landlord. The majority decision of such panel shall be made within five (5)
business days after appointment of said third architect and such decision shall
be binding upon Landlord and Tenant and judgment upon the decision of the
arbitrators may be entered in any court having jurisdiction. Landlord and Tenant
shall each pay the fees of their own architect and one-half (1/2) of the fees of
the third architect.
3.2 Space Plan. Tenant shall cause a space plan ("Space Plan") for
----------
the Tenant Improvements to be prepared (including a layout and designation of
all offices, stairways, stairwells, elevators, utility rooms, storage areas,
conference and meeting rooms and other partitioning within the Premises). The
Space Plan shall be subject to Landlord's approval, which approval shall not be
unreasonably withheld or delayed. Landlord shall advise Tenant within ten (10)
business days after Landlord's receipt of the proposed Space Plan if the Space
Plan is unsatisfactory, with a reasonable description of any matters found to be
not acceptable to Landlord. If Landlord fails to return Tenant's proposed Space
Plan to Tenant marked "Approved", "Approved as Noted" or "Disapproved" within
said ten (10) business-day period,
-2-
then Landlord shall be deemed to have approved Tenant's proposed Space Plan.
Tenant's Space Plan, as finally revised and marked or deemed approved by
Landlord, shall be initialed by Landlord and Tenant and shall be referred to as
the "Approved Space Plan". If the Approved Space Plan is not agreed upon within
five (5) business days after delivery to Tenant of a "Disapproved" Space Plan or
an "Approved as Noted" Space Plan, then Landlord or Tenant may submit the
disputed items to an arbitration panel as provided in Section 3.1 above. Any
material revisions or amendments to the Approved Space Plan shall require
Landlord's prior written approval not to be unreasonably withheld or delayed.
3.3 INTENTIONALLY DELETED
3.4 Approved Working Drawings. Tenant shall, at Tenant's sole cost
-------------------------
and expense, submit the Approved Working Drawings to the City of Mountain View
to the extent necessary to obtain any and all demolition, building and other
governmental permits as may be required by law to commence construction of the
Tenant Improvements. Tenant hereby agrees that neither Landlord nor Landlord's
consultants shall be responsible for obtaining any permits or certificates of
occupancy or other occupancy permits or approvals for the Premises and that the
obtaining of the same if required by law shall be Tenant's sole responsibility
at Tenant's sole cost. No material modifications to the Approved Working
Drawings may be made without the prior written consent of Landlord, which
consent shall not be unreasonably withheld or delayed. If Landlord fails to
disapprove any proposed, modifications to the Approved Working Drawings within
five (5) business days after receipt of written notice from Tenant or its
Architect identifying the same, then Landlord shall be deemed to have approved
such proposed modifications. Construction of the Tenant Improvements by Tenant
and the Contractor Group shall not commence unless and until Tenant has obtained
all legally required demolition, building and other governmental permits
necessary for commencing construction of the Tenant Improvements and delivered
copies of all such permits to Landlord.
3.5 Approvals Not Binding on Landlord. Landlord's and Landlord's
---------------------------------
consultants' review of the Working Drawings and Space Plan as set forth in this
Section 3 shall be for Landlord's sole purpose and shall not imply any
representation or warranty as to the adequacy or sufficiency of the same by
Landlord or Landlord's construction manager, space planners, architects,
engineers and consultants, or obligate Landlord to review the same for quality,
design, code compliance or other like matters. Accordingly, notwithstanding that
any Working Drawings or Space Plan are reviewed by Landlord or its consultants,
and notwithstanding any advice or assistance which may be rendered to Tenant by
Landlord or Landlord's consultants, Landlord and Landlord's construction
manager, space planner, architect, engineers and consultants shall have no
liability whatsoever for such review or advice and shall not be responsible for
any omissions or errors contained in the Working Drawings, Space Plan, Approved
Working Drawings, or Approved Space Plans of any nature whatsoever.
4. Construction of Tenant Improvements. Tenant, at Tenant's sole cost and
-----------------------------------
expense, shall perform or cause to be constructed within the Premises all of the
Tenant Improvements in accordance with the Approved Working Drawings and only
after receipt of all demolition, building and other governmental permits as may
be required by law to commence construction of the Tenant Improvements. No
materials used in the Tenant Improvements shall be subject to any
-3-
security interest or lien. All materials (as well as methods and processes) used
in the performance of the Tenant Improvements shall be of new and first-class
quality. Tenant shall ensure that its General Contractor and members of the
Contractor Group are familiar with all those portions of the Premises upon or
within which the Tenant Improvement Work will be performed. The Tenant
Improvements as constructed shall not materially alter or affect the exterior
appearance or the structure of the Premises or any of the mechanical,
electrical, plumbing, HVAC or other building systems serving the Premises,
unless such alterations or modifications are provided for in the Approved
Working Drawings or otherwise expressly agreed to in writing by Landlord. All
Tenant Improvements shall be performed diligently (subject to Force Majeure
delays), in a good and workmanlike manner and in accordance with any and all
applicable codes, statutes, rules, regulations, ordinances and orders of any
federal, state, county or municipal agency or other governmental body having
jurisdiction over the Premises, including, without limitation, the ADA, the
Uniform Building Code, California Health and Safety Code (S)(S) 19955 et seq.,
OSHA, 29 U.S.C. (S)(S) 651 et seq. and CAL-OSHA. During the Term or any Extended
Term, Landlord shall not be responsible for repairing or otherwise correcting
any defects in the Tenant Improvements (including any failure of the Tenant
Improvements to comply with applicable laws) that may occur during or after
completion of construction whether such defects affect the Premises or any part
thereof. Except as may be permitted under the Approved Working Drawings, Tenant
shall not demolish, remove or alter any structural portion of the Premises
without Landlord's prior written consent, which Landlord agrees not unreasonably
withhold or delay.
5. Tenant's General Contractor and Construction Contract. Tenant shall
-----------------------------------------------------
have the right to solicit bids from duly licensed reputable contractors for
construction and installation of the Tenant Improvements. Landlord shall have
the right to approve, within five (5) business days of full and complete
submittal to Landlord, each of Tenant's general contractors for the Tenant
Improvements and the form of construction contract to be entered into between
Tenant and such general contractor with respect to the construction and
installation of the Tenant Improvements, and those subcontractors and forms of
subcontracts for subcontracts where the subcontractor is providing work,
materials and/or supplies in excess of $100,000 (collectively, $100,000
Subcontractors" and "$100,000 Subcontracts", as applicable), which approvals
shall not be unreasonably withheld or delayed. Any disapproval of any of the
foregoing by Landlord shall contain a reasonable description of any matters
found to be not acceptable to Landlord. If Landlord fails to approve or
disapprove Tenant's proposed general contractor within said five (5)-business-
day period (and Landlord hereby preapproves Xxxxx Xxxxx Contractors) or to
return Tenant's proposed construction contract to Tenant marked "Approved,"
"Approved as Noted," or "Disapproved" within said five (5)-business-day period,
then Landlord shall be deemed to have approved the same. The construction
contract for the Tenant Improvements (the "Construction Contract") between
Tenant and the general contractor approved (or deemed approved) by Landlord (the
"General Contractor") shall provide, and Tenant shall exercise commercially
reasonable efforts to cause each of the $100,000 Subcontracts with the $100,000
Subcontractors to provide, that: (i) the General Contractor and each $100,000
Subcontractor shall leave all common areas (if any) at the Premises affected by
their work in a neat, orderly and safe condition at the end of each day during
construction of the Tenant Improvements; (ii) the General Contractor and each
$100,000 Subcontractor shall procure and maintain the insurance described in
Section 7 below; (iii) to the fullest extent permitted by law, the General
Contractor
-4-
and each $100,000 Subcontractor shall indemnify, defend (with counsel reasonably
acceptable to Landlord) and hold Landlord and its officers, directors, employees
and contractors harmless from and against any injury or death to any person or
damage to any property in or about the Premises resulting from the activities of
the indemnifying party, except to the extent that such injury, death or damage
results directly from negligence or willful misconduct of Landlord or its
contractors, employees or agents; (iv) the General Contractor and each $100,000
Subcontractor shall guarantee to Tenant for the benefit of Tenant and Landlord
that the portion of the Tenant Improvements for which it is responsible has been
completed in accordance with the Approved Working Drawings and shall be free
from any defects in workmanship and materials for a period of not less than one
(1) year from the date of completion thereof and that the General Contractor and
applicable $100,000 Subcontractor shall be responsible for the replacement or
repair, without additional charge, of all workmanship or materials provided by
the General Contractor pursuant to the Construction Contract or $100,000
Subcontract that may become defective within said one (1)-year period.
6. Indemnification. Tenant hereby confirms and agrees that Tenant's
---------------
indemnification and defense obligations set forth in Articles 9 and 19 of the
Lease are incorporated in full into this Work Letter as though fully set forth
herein and shall apply to all of Tenant's and the Contractor Group's
construction activities at the Premises and all work related activities
performed at the Premises by or through Tenant and the Contractor Group
hereunder during the Term. Without diminishing Tenant's rights against the
General Contractor or any other member of the Contractor Group, Tenant hereby
assumes all risk of injury or death to persons or damage to property at the
Premises and all costs relating to non-compliance with applicable laws at the
Premises caused by Tenant's construction activities at the Premises, except to
the extent such injury, death or damage is caused by Landlord's or any Landlord
Party's negligence or willful misconduct. The indemnification obligations set
forth in this Section 6 shall not be limited by available insurance proceeds and
shall survive the termination or expiration of the Lease and this Work Letter.
7. Insurance. Tenant shall cause Tenant's General Contractor and each
---------
member of the Contractor Group to maintain worker's compensation insurance with
statutory benefits and limits. Tenant shall cause Tenant's General Contractor,
and shall exercise commercially reasonable efforts to cause each $100,000
Subcontractor, to maintain comprehensive liability and property damage insurance
in an amount of not less than Two Million Dollars ($2,000,000) per occurrence
($1,000,000 for $100,000 Subcontractors) with companies and on forms reasonably
satisfactory to Landlord in its reasonable discretion. Tenant, the General
Contractor and each $100,000 Subcontractor shall, prior to commencing any work
hereunder and at all times during the entire period of construction of the
Tenant Improvements, keep current and valid certificates of the insurance
required of it hereunder on file with Landlord. Except for worker's compensation
insurance, all policies of insurance shall name Landlord and its respective
directors, officers, employees and agents as additional insureds, provide that
the insurance coverage is primary and noncontributing with any insurance carried
by Landlord, waive subrogation against Landlord with respect to property damage,
cover Tenant's indemnification obligations set forth in Section 6 above and
contain a provision giving Landlord at least thirty (30) days prior written
notice of any cancellation or material change in any insurance coverage.
-5-
8. Builder's Risk Insurance. Tenant, at Tenant's sole cost and expense,
------------------------
shall procure and maintain (or cause Tenant's contractor to procure and
maintain) during the construction of the Tenant Improvements Builder's Risk
Insurance covering One Hundred Percent (100%) of the replacement cost of all of
the Tenant Improvements, including all materials and equipment destined to
become part of the Tenant Improvements. Such insurance shall include the perils
of fire, extended coverage, vandalism and malicious mischief, and so-called "All
Risk" perils as defined and limited in the policies, but may, at Tenant's
option, exclude the perils of earthquake and flood. If during the course of
their construction any of the Tenant Improvements are damaged by a casualty
event required to be insured against by Tenant under this Section, Tenant shall
promptly repair such casualty damage (or cause the same to be repaired).
9. Landlord's Inspection Rights. During the course of construction of the
----------------------------
Tenant Improvements Landlord reserves the right to inspect the progress of the
Tenant Improvements on the terms set forth in Section 16.1 of the Lease;
provided, however, that such inspection(s) shall in no way make Landlord
responsible for any of the work of construction of the Tenant Improvements and,
as more particularly set forth in Section 3.5 above, shall not constitute a
representation or warranty by Landlord as to the design, adequacy or sufficiency
of the Tenant Improvements.
10. Notice of Nonresponsibility. Tenant shall give Landlord not more than
---------------------------
twenty (20) and not less than ten (10) business days prior written notice of the
date on which the first construction of the Tenant Improvements is scheduled to
commence to permit Landlord to post on the Premises and record with the Santa
Xxxxx County Recorder appropriate notices of nonresponsibility.
11. Payments by Tenant; Liens. All costs and expenses relating to the
-------------------------
Tenant Improvements shall be paid promptly by Tenant as they come due and
evidence of such payment shall be furnished to Landlord upon request. Tenant
shall cause any mechanic's or materialman's lien or other claim filed against
the Premises and relating to the Tenant Improvements to be released and removed
in accordance with the applicable provisions of the Lease notwithstanding any
other dispute Tenant may then have with Landlord. Should Tenant fail to remove
any such lien within the required period of time, Landlord may (at its sole
election) pay or bond over such claim and the amount paid or premium for the
bond, together with any attorneys' fees and costs incurred by Landlord in
connection therewith, shall be immediately due from Tenant to Landlord. Promptly
following completion of any portion of the Tenant Improvements by the General
Contractor and each $100,000 Subcontractor, Tenant shall deliver to Landlord
waivers of mechanic's liens executed by each such person with respect to the
completed portion of such Tenant Improvements. Promptly following completion of
the entire Tenant Improvements, Tenant shall obtain and deliver to Landlord an
unconditional waiver and release upon payment (in the form prescribed by
California Civil Code Section 3262) from the General Contractor and each
$100,000 Subcontractor.
12. Notice of Completion; Copy of "As Built" Plans. Within ten (10) days
----------------------------------------------
after final completion of construction of the Tenant Improvements, Tenant shall
cause a Notice of Completion to be recorded in the office of the Recorder of the
County of Santa Xxxxx in
-6-
accordance with Section 3093 of the California Civil Code or any successor
statute, and shall furnish a copy thereof to Landlord upon such recordation. At
the conclusion of construction, (i) Tenant shall cause the Architect and
Contractor (A) to update the Approved Working Drawings as necessary to reflect
all changes made to the Approved Working Drawings during the course of
construction, and (B) to deliver to Landlord two (2) sets of sepias of "record-
set" drawings within ninety (90) days following issuance of a certificate of
occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of
all warranties, guaranties, and operating manuals in Tenant's possession
relating to the Tenant Improvements.
13. Compliance with Rules and Regulations. All of Tenant's and the
-------------------------------------
Contractor Group's activities at the Premises shall comply with any and all
easements, covenants, conditions and restrictions affecting the Premises and any
rules and regulations attached to the Lease.
14. Lease Provisions Apply. Nothing in this Work Letter, including
----------------------
Tenant's entry into the Premises for construction of the Tenant Improvements
under this Work Letter, shall relieve either Landlord or Tenant from observing
all of the terms, covenants and conditions of the Lease required to be performed
by such party including, without limitation, all indemnification and insurance
provisions of the Lease which shall apply in full to Tenant's construction of
its Tenant Improvements, and all of the provisions of the Lease are hereby
incorporated into and made a part of this Work Letter.
15. Landlord's Cooperation. Upon Tenant's request, Landlord shall
----------------------
reasonably cooperate with Tenant, at Tenant's sole cost and expense and at no
cost to Landlord, without any liability whatsoever on Landlord's part and
without Landlord having to commit any of its staff or resources, in connection
with Tenant's construction and installation of its Tenant Improvements within
the Premises and Tenant's applications for permits, certificates and approvals
associated therewith.
16. No Third Party Beneficiaries. This Work Letter is made and entered
----------------------------
into for the sole benefit of Landlord, Tenant, any other party that may be
expressly stated in this Work Letter to benefit for this Work Letter or any
provision hereof, and their respective successors and assigns. No other persons
or entities shall have any rights or benefits under or arising out of this Work
Letter.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter as
of the date and year first above written.
LANDLORD: TENANT:
ALZA CORPORATION, a Delaware CHEMDEX corporation, a Delaware
corporation corporation
By: Xxxxxx Xxxxx By: XXXXX X. XXXXXXX
------------------------------------ -----------------------------
Its: Sr. Vice Pres., Human Resources Its: CHIEF FINANCIAL OFFICER
------------------------------------ -----------------------------
By: Xxxxx Staple By: XXXXX X. XXXXX
------------------------------------ -----------------------------
Its: Sr. Vice President & General Counsel Its: President & CEO
------------------------------------ -----------------------------
-7-
[LETTERHEAD OF XXXXX FARGO APPEARS HERE]
IRREVOCABLE LETTER OF CREDIT
ALZA Corporation Letter of Credit No. NZS330633
000 Xxxx Xxxx Xxxx Date: August 13, 1999
Xxxx Xxxx, XX 00000
Attention: Senior Vice President & General Counsel
Ladies and Gentlemen:
At the request and for the account of Chemdex Corporation, 0000 Xxxxxx Xxx,
Xxxx Xxxx, XX 00000, we hereby establish our Irrevocable Letter of Credit in
your favor in the amount of Xxx Xxxxxxx Xxxxx Xxxxxxx Xxxxxxx Xxxx Xxxxxxxx
Xxxxxx Xxxxxx Dollars (US$1,875,000.00) available with us at our above office by
payment of your draft(s) drawn on us at sight in the form of Exhibit 1 hereto
with the instructions in brackets therein complied with accompanied by your
signed and dated statement in the form of Exhibit 2 hereto with the instructions
in brackets therein complied with.
Each drawing must also be accompanied by the original of this Letter of
Credit for our endorsement on this Letter of Credit of our payment of such
drawing.
Partial and multiple drawings are permitted under this Letter of Credit,
however each drawing must be in an amount of not less than US$20,000.00.
If any instructions accompanying a drawing under this Letter of Credit
request the payment is to be made by transfer to an account with us or at
another bank, we and/or such other bank may rely on an account number specified
in such instructions even if the number identifies a person or entity different
from the intended payee.
This Letter of Credit expires at our above office on July 31, 2000, but
shall be automatically extended, without written amendment, to July 31 in each
succeeding calendar year up to, but not beyond, April 30, 2005 unless we have
sent written notice to you at your address above by registered mail or express
courier that we elect not to renew this Letter of Credit beyond the date
specified in such notice (the "Non-Renewal Expiration Date"), which Non-Renewal
Expiration Date will be July 31, 2000 or any subsequent July 31 occurring before
April 30, 2005 and be at least 60 calendar days after the date we send you such
notice.
This Letter of Credit is transferable one or more times, but in each
instance to a single transferee and only in the full amount available to be
drawn under this Letter of Credit at the time of such transfer. Any such
transfer may be effected only through ourselves and only upon presentation to us
at our above-specified office of a duly executed instrument of transfer in the
form attached hereto as Exhibit 3 with the instructions in brackets therein
complied with together with the original of this Letter of Credit. Any transfer
of this Letter of Credit may not change the place of expiration of this Letter
of Credit from our above-specified office. Each transfer shall be evidenced by
our endorsement on the reverse of the original of this Letter of Credit, and we
shall deliver the original of this Letter of Credit so endorsed to the
transferee. All commissions and charges in connection with this transfer are for
the account of Chemdex Corporation.
This is an integral part of Xxxxx Fargo Bank, N.A. Letter of Credit No.
NZS330633
Page Two
This Letter of Credit is subject to the Uniform Customs and Practice for
Documentary Credits (1993 revision), International Chamber of Commerce
Publication No. 500, and engages us in accordance therewith.
Very truly yours,
XXXXX FARGO BANK N.A.
BY: /s/ [ILLEGIBLE]^^
-----------------------------
(AUTHORIZED SIGNATURE)
Exhibit 1
Xxxxx Fargo Bank, N.A
Letter of Credit No. NZS330633
================================================================================
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx
Xxx Xxxxxxxxx, XX 00000
Attention: Manager, Standby Letter of Credit Dept.
DRAFT
Date of Draft: [insert date]
To the order of [insert Beneficiary Name], pay [insert amount of
drawing in words] UNITED STATES DOLLARS (U.S. $ [insert amount of drawing in
numbers]) at sight
For value received under Letter of Credit No. NZS330633
"Drawn under Xxxxx Fargo Bank, N.A. Letter of Credit No. NZS330633
dated August 13, 1999."
[insert Beneficiary Name]
By: [insert signature]
Its: [insert title]
================================================================================
Exhibit 2
Xxxxx Fargo Bank, N.A
Letter of Credit No. NZS330633
================================================================================
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx
Xxx Xxxxxxxxx, XX 00000
Attention: Manager, Standby Letter of Credit Dept.
Re: Letter of Credit No. NZS330633
Ladies and Gentlemen:
1. The undersigned Beneficiary, [insert Beneficiary Name], is Landlord
under that certain Office Lease dated August 13, 1999 ("Lease") with Chemdex
Corporation, a Delaware corporation, as Tenant.
2. The undersigned Beneficiary is entitled to payment under the Lease in
the amount of U.S.$[insert amount of draft which accompanies this statement]
(the "Draw Amount") in accordance with the applicable provisions of the Lease
(as the same may have been amended to date), which is the same amount as the
Draft accompanying this Certificate and is less than or equal to the amount
currently available under the Letter of Credit.
3. The individual executing this Certificate on behalf of Beneficiary is
a duly authorized officer of Beneficiary.
Date: [insert date] [insert Beneficiary Name]
By: [insert signature]
Its: [insert title]
================================================================================
Exhibit 3
Xxxxx Fargo Bank, N.A
Letter of Credit No. NZS330633
================================================================================
Date: [insert date]
Xxxxx Fargo Bank, N.A.
Trade Services Division, Northern California
000 Xxxxxx Xxxxxx, 00xx Xxxxx
Xxx Xxxxxxxxx, Xxxxxxxxxx 00000
Attention: Manager, Standby Letter of Credit Department
Subject: Your Letter of Credit No. NZS330633
Ladies and Gentlemen:
For value received, we hereby irrevocably assign and transfer all our
rights under the above-captioned Letter of Credit, as heretofore and hereafter
amended, extended or increased, to:
____________________________
[ insert Name of Transferee]
____________________________
____________________________
[ insert Address of Transferee]
By this transfer, all of our rights in the Letter of Credit are transferred
to the transferee, and the transferee shall have sole rights as beneficiary
under the Letter of Credit, including sole rights relating to any amendments,
whether increases or extensions or other amendments, and whether now existing or
hereafter made. You are hereby irrevocably instructed to advise future
amendment(s) of the Letter of Credit to the transferee without our consent or
notice to us.
You are hereby advised that [ insert Name of Transferee] succeeded to all
of beneficiary's right, title and interest under that certain Office Lease dated
August 13, 1999 (as the same may have been amended to date), with Chemdex
Corporation, a Delaware corporation, as Tenant.
Enclosed are the original Letter of Credit and the original of all
amendments to this date. Please notify the transferee of this Transfer and of
the terms and conditions of the Letter of Credit as transferred. All fees and
charges in connection with this Transfer are for the account of Chemdex
Corporation.
Very truly yours,
[Insert Name of Beneficiary]
By: [insert signature]
Its: [insert title]
Signature of Transferor Guaranteed
[Insert Name of Bank]
By: [insert signature]
Name: [insert typed or printed name]
Title: [insert title]
================================================================================
to benefit for this Work Letter or any provision hereof, and their respective
successors and assigns. No other persons or entities shall have any rights or
benefits under or arising out of this Work Letter.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter
as of the date and year first above written.
LANDLORD: TENANT:
ALZA CORPORATION, a Delaware CHEMDEX corporation, a Delaware
corporation corporation
By: /s/ Xxxxxx Xxxxx By: /s/ Xxxxx X. Xxxxxxx
------------------------------------ --------------------------------
Xxxxxx Xxxxx XXXXX X. XXXXXXX
Its: Sr. Vice Pres., Human Resources Its: CHIEF FINANCIAL OFFICER
------------------------------------ --------------------------------
By: /s/ Xxxxx Staple By: /s/ Xxxxx X. Xxxxx
------------------------------------ --------------------------------
Xxxxx Staple XXXXX X. XXXXX
Its: Sr. Vice President & Gen. Counsel Its: President & CEO
------------------------------------ --------------------------------
-8-
EXHIBIT E
---------
TERMS TO BE INCORPORATED IN LEASE SUBORDINATION,
ATTORNMENT AND NONDISTURBANCE AGREEMENT
THIS AGREEMENT is made this _______ day of ____________________, by and
between CHEMDEX CORPORATION, a Delaware Corporation ("Tenant") and ____________
_________________________ ("Lender"):
RECITALS
A. Lender is the holder of that certain promissory note ("Note") issued by
ALZA CORPORATION ("Landlord") dated ____________________ in the principal sum of
_______________________ DOLLARS ($_____________)and of the deed of trust
recorded on ________________ ("Mortgage"), which Mortgage encumbers the real
property (the "Mortgaged Property") commonly known as 0000 Xxxxxxxx Xxxxxx and
0000 Xxxxxxxx Xxxxxx, Xxxxxxxx Xxxx, Xxxxxxxxxx, which Mortgaged Property is
more particularly described in the Mortgage.
B. Landlord and Tenant entered into that certain Office Lease ("Lease")
dated August 13, 1999, by which Tenant leased from Landlord the Mortgaged
Property, all as more fully described in the Lease.
C. Tenant desires to be able to obtain the advantages of the Lease and
occupancy thereunder in the event of foreclosure of the Mortgage and Lender
wishes to have Tenant confirm the priority of the Mortgage over the Lease as the
Lease relates to the Mortgaged Property.
NOW, THEREFORE, in consideration of the mutual covenants and conditions set
forth hereinbelow, the parties hereto agree as follows:
1. Tenant hereby covenants and agrees that all its rights, title and
interest whatsoever under the Lease as the Lease relates to the Mortgaged
Property is and shall at all times be and remain unconditionally subject and
subordinate to lien and charge of the Mortgage and to all the terms, conditions
and provisions thereof, to all advances made or to be made thereunder or under
the Note, and to any increases, renewals, extensions, modifications,
substitutions, consolidations or replacements thereof or of the Note and the
Mortgage.
2. So long as Tenant is not in default (beyond any period given Tenant in
the Lease to cure such defaults) in the payment of rent or additional charges or
in the performance of any of the other terms, covenants or conditions of the
Lease on Tenant's part to be performed, Tenant shall not be disturbed by Lender
in its possession of the Mortgaged Property during the term of the Lease, or any
extension or renewal thereof, or in the enjoyment of its rights under the Lease.
3. If the interest of the Landlord under the Lease as the Lease relates to
the Mortgaged Property shall be acquired by Lender or any purchaser
("Purchaser") by reason of exercise of the power of sale or the foreclosure of
the Mortgage or other proceedings brought to enforce the rights of the holder
thereof, by deed in lieu of foreclosure or by any other method, and Lender or
-1-
Purchaser succeeds to the interest of Landlord under the Lease, Tenant shall
attorn to Lender or Purchaser as its landlord, said attornment to be effective
and self-operative without the execution of any other instruments on the part of
either party hereto immediately upon Lender's or Purchaser's succeeding to the
interest of the Landlord under the Lease, and the Lease shall continue in
accordance with its terms between Tenant as tenant and Lender or Purchaser as
landlord, provided however that:
(a) Lender shall not be personally liable under the Lease and Lender's
liability under the Lease shall be limited to the equity interest of Lender in
the Mortgaged Property as provided in Section 25.3 of the Lease;
(b) Lender shall not be liable for any act or omission of any prior
landlord (including Landlord);
(c) Lender shall not be subject to any offsets or defenses which
Tenant might have against any prior landlord (including Landlord);
(d) Lender shall not be liable for any damages or other relief
attributable to any prior latent defects in the Mortgaged Property; and
(e) Lender shall not be bound by any prepayment of rent, additional
rent or deposit, rental security, letter of credit or any other sums deposited
with any prior landlord (including Landlord) under the Lease unless actually
received by Lender.
4. Tenant certifies to Lender that except as provided below, (i) the Lease
is presently in full force and effect with no defaults thereunder by Landlord or
by Tenant and unmodified; (ii) the term thereof has commenced and the full
rental is now accruing thereunder, (iii) Tenant has accepted possession of the
Premises and that any improvements required by the terms of the Lease to be made
by Landlord have been completed to the satisfaction of Tenant; (iv) no rent
under the Lease has been paid more than thirty (30) days in advance of its due
date; (v) the address for notices to be sent to Tenant is as set forth in the
Lease; and (vi) Tenant has no charge, lien, claim or offset under the Lease or
otherwise, against rents or other charges due or to become due thereunder.
5. Tenant agrees with Lender that from and after the date hereof, Tenant
will not terminate or seek to terminate the Lease by reason of my act or
omission of Landlord thereunder until Tenant shall have given written notice, by
registered or certified mail, return receipt requested, of said act or omission
to Lender, which notice shall be addressed to Lender and until the grace period
as set forth in the Lease shall have elapsed following the giving of such
notice, during which period Lender shall have the right, but shall not be
obligated, to remedy such act or omission.
6. Nothing in this Agreement shall be deemed to be or construed to be an
agreement by Lender to perform any covenant of Landlord under the Lease unless
and until it obtains title to the Mortgaged Property by power of sale or
judicial foreclosure or deed in lieu thereof or obtains possession of the
Property pursuant to the terms of the Mortgage.
-2-
7. This Agreement shall inure to the benefit of and shall be binding upon
Tenant and Lender, and their respective heirs, personal representatives,
successors and assigns. This Agreement may not be altered, modified or amended
except in writing signed by all of the parties hereto. In the event any one or
more of the provisions contained in this Agreement shall for any reason be held
to be invalid, illegal or unenforceable in any respect, such invalidity,
illegality or unenforceability shall not affect any other provisions of this
Agreement, but this Agreement shall be construed as if such invalid, illegal or
unenforceable provision had never been contained herein. This Agreement shall be
governed by and construed according to the laws of the State of California.
IN WITNESS WHEREOF, Lender and Tenant have executed this Agreement as of
the date and year first above written.
LENDER: TENANT:
CHEMDEX CORPORATION, a
Delaware Corporation
By:__________________________ By:______________________________
Its:_________________________ Its:_____________________________
-3-
SCHEDULE 2
List of Groundwater Monitoring Reports
1. Letter dated May 15, 1998 from the San Francisco Bay Regional Water
Quality Control Board to ALZA Corporation concerning 0000/0000 Xxxxxxxx Xxxxxx,
Xxxxxxxx View.
2. Letter and Summary of Environmental Condition dated June 17, 1999 from
Aquifer Services, Inc. to ALZA Corporation concerning 0000/0000 Xxxxxxxx Xxxxxx
and 0000 Xxxxxxx Xxxx, Xxxxxxxx View.
3. Groundwater Monitoring Report for the Quarterly Reporting Period January
1 through March 31, 1999 prepared for Spectra-Phipers Lasers, Inc. and Teledyne
Semiconductor dated April 30, 1999.
-1-
Building M6A - First Floor
[Floor Plan]
Building M6A - Second Floor
[Floor Plan]
Building M6B - First Floor
[Floor Plan]
Building M6B - Second Floor
[Floor Plan]
8PAGE>
Estimated Furniture Value
in Bldgs. M6A, M6B
-----------------------------------------------------------------------------------------------------------
Description Brand Quantity New Cost Ea Cost Total
-----------------------------------------------------------------------------------------------------------
-----------------------------------------------------------------------------------------------------------
Bookcase: Short 42" - 48" Various Laminate 21 $ 260.00 $ 5,460.00
-----------------------------------------------------------------------------------------------------------
Bookcase: Short 42" - 48" Various Metal 18 $ 180.00 $ 3,240.00
-----------------------------------------------------------------------------------------------------------
Bookcase: Short 42" - 48" Various Wood 31 $ 550.00 $ 17,050.00
-----------------------------------------------------------------------------------------------------------
Bookcase: Tall 55" - 72" Various Laminate 11 $ 350.00 $ 3,850.00
-----------------------------------------------------------------------------------------------------------
Bookcase: Tall 55" - 72" Various Metal 18 $ 225.00 $ 4,050.00
-----------------------------------------------------------------------------------------------------------
Bookcase: Tall 55" - 72" Various Wood 17 $ 950.00 $ 16,150.00
-----------------------------------------------------------------------------------------------------------
Cabinet, Metal Utility Various 10 $ 450.00 $ 4,500.00
-----------------------------------------------------------------------------------------------------------
Cabinet, Wood Various 4 $ 1,200.00 $ 4,800.00
-----------------------------------------------------------------------------------------------------------
Chair, Conf Room Various 66 $ 500.00 $ 33,000.00
-----------------------------------------------------------------------------------------------------------
Chair, Exec Various 6 $ 800.00 $ 4,800.00
-----------------------------------------------------------------------------------------------------------
Chair, Side Various 195 $ 300.00 $ 58,500.00
-----------------------------------------------------------------------------------------------------------
Chair, Side: Wood Steelcase 24 $ 240.00 $ 5,760.00
-----------------------------------------------------------------------------------------------------------
Chair, Lobby Various 4 $ 600.00 $ 2,400.00
-----------------------------------------------------------------------------------------------------------
Chair, Lunch Room Various 35 $ 180.00 $ 6,300.00
-----------------------------------------------------------------------------------------------------------
Chair, Task Steelcase Criterion 113 $ 500.00 $ 56,500.00
-----------------------------------------------------------------------------------------------------------
Chair, Task X.Xxxxxx Aeron 9 $ 800.00 $ 7,200.00
-----------------------------------------------------------------------------------------------------------
Chair, Task Various 420 $ 500.00 $ 10,000.00
-----------------------------------------------------------------------------------------------------------
Credenza, Laminate Various 9 $ 550.00 $ 4,950.00
-----------------------------------------------------------------------------------------------------------
Credenza, Wood Various 35 $ 850.00 $ 29,750.00
-----------------------------------------------------------------------------------------------------------
Cubicle, approx 8'x10' Steelcase 9000 123 $ 6,000.00 $ 38,000.00
-----------------------------------------------------------------------------------------------------------
Desk, 3-Part Laminate Sequus 46 $ 1,200.00 $ 55,200.00
-----------------------------------------------------------------------------------------------------------
Desk, Laminate Various 31 $ 550.00 $ 17,050.00
-----------------------------------------------------------------------------------------------------------
Desk, Large Wood Various 10 $ 650.00 $ 6,500.00
-----------------------------------------------------------------------------------------------------------
Desk, Metal w/Wood Dbl Ped Various 52 $ 800.00 $ 41,600.00
-----------------------------------------------------------------------------------------------------------
Desk, w/Return Steelcase 9000 60 $ 1,630.00 $ 97,800.00
-----------------------------------------------------------------------------------------------------------
Desk, w/Return Various Wood/Metal 23 $ 500.00 $ 11,500.00
-----------------------------------------------------------------------------------------------------------
Desk, Wood, Exec Steelcase 29 $ 2,500.00 $ 72,500.00
-----------------------------------------------------------------------------------------------------------
Desk, Wood, Small Various 44 $ 700.00 $ 30,800.00
-----------------------------------------------------------------------------------------------------------
File Cabinet, 2-Drawer Various 113 $ 365.00 $ 41,245.00
-----------------------------------------------------------------------------------------------------------
File Cabinet, 3-Drawer Various 29 $ 500.00 $ 14,500.00
-----------------------------------------------------------------------------------------------------------
File Cabinet, 4-Drawer Various 145 $ 800.00 $ 16,000.00
-----------------------------------------------------------------------------------------------------------
File Cabinet, 5-Drawer Various 48 $ 2,500.00 $ 20,000.00
-----------------------------------------------------------------------------------------------------------
File Cabinet, Vertical Various 5 $ 250.00 $ 1,250.00
-----------------------------------------------------------------------------------------------------------
File Cabinet High Density Various Metal 17 $ 2,500.00 $ 42,500.00
-----------------------------------------------------------------------------------------------------------
File Cabinet Misc Various 48 $ 300.00 $ 14,400.00
-----------------------------------------------------------------------------------------------------------
File Cabinet 4-Dr Fire-Proof Fire-King 2 $ 4,000.00 $ 8,000.00
-----------------------------------------------------------------------------------------------------------
File, Flat Wood 2 $ 2,500.00 $ 5,000.00
-----------------------------------------------------------------------------------------------------------
Keyboard Trays WorkRite (85%) 367 $ 200.00 $ 73,400.00
-----------------------------------------------------------------------------------------------------------
Safe, Small Various 2 $ 1,500.00 $ 3,000.00
-----------------------------------------------------------------------------------------------------------
Server Room Racking Wrightline 2 $12,000.00 $ 24,000.00
-----------------------------------------------------------------------------------------------------------
Sofa, Sectional Generic 1 $ 6,000.00 $ 25,000.00
-----------------------------------------------------------------------------------------------------------
Table, Computer Human Factor 8 $ 850.00 $ 6,800.00
-----------------------------------------------------------------------------------------------------------
Table, Computer Various 22 $ 350.00 $ 7,700.00
-----------------------------------------------------------------------------------------------------------
Table, Conference Room Various 5 $ 5,000.00 $ 25,000.00
-----------------------------------------------------------------------------------------------------------
Table, Large Round Various 29 $ 750.00 $ 21,750.00
-----------------------------------------------------------------------------------------------------------
Table, Lunch Laminate/Metal 4 $ 450.00 $ 1,800.00
-----------------------------------------------------------------------------------------------------------
Table, Misc Various 66 $ 300.00 $ 19,800.00
-----------------------------------------------------------------------------------------------------------
Estimated Furniture Value
August 13, 1999 in Bldgs. M6A, MGB
Estimated Furniture Value
in Bldgs. M6A, M6B
Table, Printer/Computer Various 11 $250.00 $ 2,750.00
---------------------------------------------------------------------------------------------------------
Table, Small Round Various 50 $265.00 $ 13,250.00
---------------------------------------------------------------------------------------------------------
Table, Task 30x60 Various 16 $350.00 $ 5,600.00
---------------------------------------------------------------------------------------------------------
Table, Training Various 23 $650.00 $ 14,950.00
---------------------------------------------------------------------------------------------------------
$2,156,905.00
=============
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------
Estimated Furniture Value
August 13, 1999 in Bldgs. M6A, M6B 2
