COMMERCIAL LEASE AGREEMENT
MEPC QUORUM PROPERTIES II INC.,
as LANDLORD,
and
MANNATECH, INC.
as TENANT
pertaining to 74,476 square feet
in Freeport North Industrial Park [Phase III]
Coppell, Texas
COMMERCIAL LEASE AGREEMENT
THIS COMMERCIAL LEASE AGREEMENT (this LEASE) is made and entered into by
and between MEPC QUORUM PROPERTIES II INC., a Delaware corporation (LANDLORD),
and MANNATECH, INC., a Texas corporation (TENANT).
1. PREMISES/LEASE TERM. In consideration of the mutual obligations of
Landlord and Tenant set forth herein, Landlord leases to Tenant, and Tenant
hereby takes from Landlord, approximately 74,476 square feet (the PREMISES) in
the Building (hereinafter defined) to be constructed by Landlord on an
approximate 27.8 acre tract of land located in the Freeport Xxxxx Xxxxxxxxxx
Xxxx, Xxxx xx Xxxxxxx, Xxxxxx Xxxxxx, Xxxxx, as more particularly described on
EXHIBIT "A" attached hereto and incorporated herein by reference (the LAND)
and illustrated and illustrated on the Site Plan (herein so called) attached
hereto as EXHIBIT "C" and incorporated herein by reference, together with the
non-exclusive use of all rights, privileges, easements, appurtenances, and
amenities belonging to or in any way pertaining to the Project (hereinafter
defined) for a term (the LEASE TERM or the TERM OF THIS LEASE) beginning on
the Commencement Date (hereinafter defined) and ending at 11:59 p.m. on the
last day of the month that is one hundred twenty (120) complete calendar
months after the Rent Commencement Date (hereinafter defined). If the Rent
Commencement Date occurs on the first day of a calendar month, then the month
in which the Rent Commencement Date occurs shall be the first complete
calendar month after the occurrence of the Rent Commencement Date for purposes
of determining such one hundred twenty (120) complete calendar month period.
That portion of the Land upon which the Building (and its appurtenances) are
constructed, the Building (including the Premises comprising a part thereof)
and any other improvements constructed by or on behalf of Landlord on such
portion of the Land are collectively referred to herein as the PROJECT. The
Project is further described by illustration on the Site Plan.
2. IMPROVEMENTS TO BE CONSTRUCTED BY LANDLORD.
A. BUILDING. Landlord agrees to construct on the Land an
approximate 297,902 square foot warehouse building structure (the BUILDING)
containing the features generally described on EXHIBIT "B" attached hereto and
incorporated herein by reference and generally situated as shown on the Site
Plan (herein so called) attached hereto as EXHIBIT "C" and incorporated herein
by reference. Landlord agrees to construct the Building in a good and
workmanlike manner.
B. CONSTRUCTION COSTS. Subject to the terms of this paragraph,
Landlord will pay all costs of constructing the Building and any other
improvements described on EXHIBIT "B". Notwithstanding the preceding sentence,
Tenant shall be responsible for the following:
(1) If Landlord performs, at Tenant's request, any work over
and above the work generally described on EXHIBIT "B" (herein, the
ADDITIONAL WORK), the Additional Work together with the cost of preparing
plans and specifications for same will be at Tenant's expense. Landlord
will not be obligated to perform any such Additional Work until Tenant
pays Landlord ten percent (10%) of the estimated cost of the Additional
Work, as estimated by Landlord, with the actual cost of the Additional
Work, less the initial payment by Tenant, being due within ten (10) days
after substantial completion of the Additional Work.
(2) All costs or expenses incurred or suffered by Landlord that
are caused by Tenant Delays. A TENANT DELAY(S) shall mean any delay in
the completion of the Building or any delay in the occurrence of the
Commencement Date caused by a Tenant Party, any delay resulting from the
installation by Tenant or any Tenant Party of any property or equipment
of Tenant in or on the Premises prior to the Commencement Date, any delay
resulting from any request by Tenant for any change or modification to
the plans and specifications for the Building, any delay caused by any
Additional Work requested by Tenant, and any delay due to interference by
Tenant or any Tenant Party with Landlord's engineers, consultants,
contractors or otherwise. As used in this Lease, a TENANT PARTY shall
mean one or more of Tenant, its agents, employees, officers, partners or
contractors.
COMMERCIAL LEASE AGREEMENT PAGE 1
3. COMMENCEMENT DATE/ACCEPTANCE OF PREMISES.
A. COMMENCEMENT DATE. The COMMENCEMENT DATE shall be the date upon
which Landlord's architect reasonably determines that construction of the
Building shell has progressed to a point sufficient to allow Tenant to enter
the Premises and perform any finish work Tenant requires in the Premises (such
to be subject to Paragraph 6 below), provided that this date shall be adjusted
backward (I.E., to an earlier date) by one (1) day for each day that a Tenant
Delay exists. Subject to Tenant Delays and Force Majeure, Landlord agrees to
use reasonable efforts to cause the Commencement Date to occur by October 13,
1997. Tenant's entry into the Premises for purposes of commencing such finish
work shall constitute Tenant's acknowledgement that (i) it has inspected and
accepts the Building and the Project, (ii) the Premises is suitable for the
purpose for which it is leased, subject to completion by Tenant of any finish
work Tenant requires, (iii) the Building and the Project are in good and
satisfactory condition, and (iv) no representations as to the repair of the
Premises or the Project, nor promises to alter, remodel or improve the
Premises or the Project which have been made by Landlord remain unsatisfied.
Upon determination of the actual Commencement Date and Tenant's entry into the
Premises, Tenant agrees to execute an Acceptance of Premises Memorandum in the
form attached hereto and made a part hereof as EXHIBIT "E"; provided, however,
that Tenant's failure to execute the Acceptance of Premises Memorandum will
not delay the occurrence of the Commencement Date.
4. RENT.
A. BASE MONTHLY RENT. Tenant agrees to pay to Landlord rent for
the Premises, in advance, as follows (BASE MONTHLY RENT):
- Beginning on the Rent Commencement Date and continuing through the
last day of the sixtieth (60th) complete calendar month after the
month in which the Rent Commencement Date occurs, $20,170.58 per month
($242,046.96 on an annualized basis); and
- Beginning on the first day of the sixty-first (61st) calendar month
after the month in which the Rent Commencement Date occurs, and
continuing through the remainder of the Lease Term, $23,273.75 per
month ($279,285 on an annualized basis).
B. ADDITIONAL RENT. Tenant agrees to reimburse Landlord for
Tenant's Proportionate Share (hereinafter defined) of (i) Real Property Taxes
(hereinafter defined), (ii) Landlord's actual cost of obtaining and
maintaining Landlord's Insurance (hereinafter defined), and (iii) the actual
cost of any maintenance performed by Landlord under Paragraph 12A(2) below or
which, in Landlord's reasonable discretion, is for the benefit of the Project
as a whole and not reasonably allocable to any specific tenant or tenants
(collectively, the ADJUSTMENTS). During each month of the term of this Lease,
on the same day that Base Monthly Rent is due hereunder, Tenant shall pay to
Landlord as additional Rent an amount equal to 1/12 of Tenant's Proportionate
Share of the estimated total annual cost of the Adjustments, as determined by
Landlord. Tenant authorizes Landlord to use such funds to pay such costs. The
initial monthly payments of Adjustments are based upon Landlord's good faith
estimates for the current Lease Year (hereinafter defined) and shall be
increased or decreased each Lease Year to reflect the projected actual cost of
all Adjustments. If Tenant's total payments are less than Tenant's
Proportionate Share of the actual costs of all such items, Tenant shall pay
the difference to Landlord within ten (10) days after demand. If the total
payments of Tenant are more than Tenant's Proportionate Share of the actual
costs of all such items, Landlord shall notify Tenant of such and retain such
excess and credit it against Tenant's next. monthly estimated payments of
Adjustments. The amount of the Base Monthly Rent and the estimated monthly
payments (based upon a complete calendar month) of Tenant's Proportionate
Share of the Adjustments for the Lease Year in which the date of this Lease
occurs are as follows:
(1) Base Monthly Rent $20,170.58
(2) Real Property Taxes $ 3,723.80
(3) Insurance $ 310.32
(4) Maintenance $ 620.63
----------
Initial Monthly Payment Total $24,825.33
----------
----------
COMMERCIAL LEASE AGREEMENT PAGE 2
TENANT'S PROPORTIONATE SHARE, as used in this Lease, shall mean a
fraction, the numerator of which is the number of square feet of rentable area
contained in the Premises and the denominator of which is the entire number of
square feet of rentable area contained in the Building (as to costs which do
not materially vary based on the occupancy of the Building) or is the entire
rented area contained in the Building (as to costs which do materially vary
based on the occupancy of the Building). If the Project is part of a larger
development constructed by Landlord on the Land (the DEVELOPMENT) and the
Building and one or more other buildings on parts of the Development other
than the Project share the benefit of or may properly be allocated a portion
of any expense, Landlord shall reasonably allocate any such expense among the
Building and such other building(s) prior to applying Tenant's Proportionate
Share to such expense.
C. PAYMENT OF RENT. Base Monthly Rent and Adjustments shall be due
and payable, in advance, beginning on that date which is ninety (90) days
after the Commencement Date (the RENT COMMENCEMENT DATE); provided that one
(1) full installment of Base Monthly Rent and Adjustments totalling $24,825.33
is due and payable on the date of this Lease, such to be applied to the first
installment of Base Monthly Rent and Adjustments due on the Rent Commencement
Date and thereafter applied to Base Monthly Rent and Adjustments until fully
applied. Any installment of Base Monthly Rent or Adjustments due for any
fractional calendar month shall be prorated based upon the actual number of
days in that month. If the Rent Commencement Date occurs on the first day of a
calendar month, then the month in which the Rent Commencement Date occurs
shall be the first complete calendar month after the occurrence of the Rent
Commencement Date for purposes of determining the date upon which Base Monthly
Rent adjusts. As used in this Lease, RENT shall mean the Base Monthly Rent and
all other amounts provided for in this Lease to be paid by Tenant to Landlord,
all of which shall constitute rental in consideration for this Lease and the
leasing of the Premises. All Rent (hereinafter defined) shall be paid at the
times and in the amounts provided for herein in legal tender of the United
States of America to Landlord at the address specified in Paragraph 32 hereof
or to such other person or at such other address as Landlord may from time to
time designate in writing. Rent shall be paid without notice, demand,
abatement, deduction or offset (unless expressly provided for elsewhere in
this Lease) and shall be a covenant of Tenant independent of any obligation of
Landlord under this Lease. Tenant's obligation to pay any installment of Rent
shall not be deemed satisfied until such installment of Rent has actually been
received by Landlord.
D. AUDIT OF ADJUSTMENTS. Within ninety (90) days after the end of
each Lease Year, Landlord will provide to Tenant a statement of Adjustments
paid by Landlord for the just ended Lease Year. Tenant may at any time within
thirty (30) days after its receipt of Landlord's statement, but in any event
upon ten (10) days advance written notice to Landlord, audit, inspect and copy
the books and records of Landlord with respect to the Adjustments and make any
written objections Tenant may have to Landlord's determination of same.
Landlord shall cooperate with Tenant in providing Tenant reasonable access to
its books and records during normal business hours for this purpose. If the
results of any inspection or audit show an overcharge to Tenant of more than
five percent (5%) of the actual amount of Adjustments owed by Tenant, then
Landlord shall pay the reasonable costs of such audit (assuming the audit is
performed by a third party unaffiliated with Tenant and not including the
travel, meal or incidental expenses of the auditor), and Landlord shall credit
or refund to Tenant any overcharge of such items as discovered by the
inspection or audit within thirty (30) days of completion of such inspection
or audit. In the event such audit discloses an overcharge to Tenant of up to
but no more than five percent, there will be no credit or refund to Tenant,
and Tenant will pay the cost of the audit. In the event such audit discloses
an undercharge of Adjustments billed to Tenant, Tenant shall pay Landlord the
amount of such undercharge within thirty (30) days of the completion of such
audit and the cost of the audit. In the event Landlord disputes the amount of
Adjustments or Tenant's Proportionate Share thereof, as determined by Tenant's
audit, Landlord shall have a period of thirty (30) days from its receipt of
Tenant's audit results to have its own independent auditor inspect Tenant's
audit and the books and records pertaining to the Adjustments and deliver the
results thereof to Tenant. Landlord's failure to conduct such an audit and
deliver the results thereof to Tenant within such thirty (30) day period shall
constitute acceptance by Landlord of the results of Tenant's audit. If
Landlord delivers Tenant Landlord's audit within such thirty (30) day period,
Tenant shall have thirty (30) days to review and object to the results
thereof. The results of Landlord's audit shall be conclusive and binding upon
Tenant unless Tenant objects in writing, such objections to be specific, to
such results within such thirty (30) day period.
E. LEASE YEAR. A LEASE YEAR shall mean a twelve (12) month period
commencing each January 1st and ending on the following December 31st;
provided, however, Landlord may from time to time (but no more often than once
every eighteen (18) months) change the twelve (12) month period designated as
a Lease Year by notice thereof to Tenant, in which event the obligations of
Tenant measured by Lease Years shall be prorated as appropriate during any
COMMERCIAL LEASE AGREEMENT PAGE 3
Lease Year of less than twelve (12) months based on the number of days in any
such Lease Year divided by 365; and provided, further, the first and last
Lease Years and all obligations of Tenant measured by such Lease Years, shall
be prorated as appropriate based upon the number of days in the applicable
Lease Year during the term of this Lease divided by 365.
F. INTEREST ON DELINQUENT RENT. Any Rent due from Tenant to
Landlord which is not paid when due shall bear interest from and after the
expiration of any applicable cure or grace period until paid at the lower of
(i) eighteen percent (18%) per annum or (ii) the highest rate from time to
time allowed by applicable law, from the date such payment is due until paid,
but the payment of such interest shall not excuse or cure the default. This
provision for default interest shall be in addition to all of Landlord's other
rights and remedies hereunder or at law or equity and shall not be construed
as liquidated damages or as limiting Landlord's remedies in any manner. Any
assessed default interest will be additional Rent owed hereunder.
5. COMPLIANCE WITH LAWS. Tenant shall comply with all Applicable Laws
in connection with Tenant's use and occupancy of the Premises and Tenant's
performance of its obligations under this Lease, all at Tenant's expense. As
used herein the term APPLICABLE LAWS means and includes any and all federal,
state and local laws, ordinances, orders, deed restrictions (specifically
including the Declaration of Protective Covenants dated May 18, 1995 and
recorded in Volume 95098, Page 924, ET SEQ. of the Official Public Records of
Real Property in Dallas County, Texas (as amended, modified, supplemented,
restated and assigned from time to time, the DECLARATION)), easements of
record, rules, and regulations of all governmental bodies (state, federal, and
municipal) applicable to or having jurisdiction over the use, occupancy,
operation and maintenance of the Project, including without limitation, the
Americans With Disabilities Act of 1990, as amended from time to time (ADA),
and Environmental Laws (hereinafter defined), as such may be amended or
modified from time to time. Notwithstanding the above, if any improvement,
modification or alteration of the Premises or the Project, or any portion
thereof, is required to bring same into compliance with the ADA, or any other
Applicable Laws, and (i) Tenant is not otherwise expressly responsible for
such improvement, modification or alteration under this Lease, (ii) the
necessity for such improvement, modification or alteration was not caused, in
whole or in part, by Tenant or any Tenant Party, and (iii) the necessity for
such improvement, modification or alteration was not due to the specific use
of the Premises by Tenant, then Landlord will undertake such improvement,
modification or alteration and the cost thereof will be charged back to (A)
Tenant to the extent that the improvement, modification or alteration affects
only or is totally within the Premises, and (B) all tenants of the Project,
including Tenant, to the extent that the improvement, modification or
alteration affects the Project as a whole and not any one tenant's particular
leased premises, with each tenant paying its Proportionate Share thereof. Such
costs will be charged over the useful life of the subject improvement,
modification or alteration, as determined under generally accepted accounting
principles, with the assumption that the only portion of such expense
chargeable for any one Lease Year will be a fraction of such expense, the
numerator of which is one and the denominator of which is the estimated useful
life of the improvement, modification or alteration.
6. ALTERATIONS AND IMPROVEMENTS BY TENANT.
A. CONDITIONS PRECEDENT TO ALL ALTERATIONS AND IMPROVEMENTS.
Except as expressly permitted by this Paragraph 6, or unless otherwise agreed
to in writing between Landlord and Tenant, Tenant may not make or permit any
alterations, improvements, or additions in or to the Premises or the Project
without Landlord's prior written consent. All alterations and improvements
desired by Tenant are subject to the following conditions/requirements:
(1) Subject to subparagraph 6B below, all alterations,
improvements and additions will be at the sole cost and expense of Tenant;
(2) All alterations, improvements and additions in and to the
Premises requested by Tenant must be made in accordance with plans and
specifications first approved in writing by Landlord;
(3) Tenant's contractors and subcontractors are subject to
Landlord's prior approval. In addition, each of Tenant's contractor(s) and
subcontractor(s) must deliver evidence satisfactory to Landlord that the
insurance specified on EXHIBIT "F" (attached hereto and incorporated herein
by reference) is in force prior to commencing work;
COMMERCIAL LEASE AGREEMENT PAGE 4
(4) All alterations, improvements and additions made by Tenant
must comply with all Applicable Laws including, specifically, the ADA,
and applicable building permits and certificates of occupancy. Landlord's
approval of Tenant's plans and specifications for the alterations or
improvements will not act as a confirmation or agreement by Landlord that
the improvements and alterations comply with Applicable Laws;
(5) Tenant must deliver to Landlord evidence that Tenant has
obtained all necessary governmental permits and approvals for the
improvements, alterations and additions prior to starting any work;
(6) All alterations, improvements and additions must be done
in a good and workmanlike manner so as not to damage or alter the primary
structure or structural qualities or the utility or other systems of the
Premises or the Building and is subject to approval by Landlord during
and after construction, in its sole discretion. Tenant agrees to meet
with Landlord's project manager, who for purposes of this Lease shall be
Xxx Xxxxxx until further notice, as deemed reasonably necessary by such
project manager during any construction by Tenant pursuant to this
Paragraph 6 so that Landlord can evaluate the progress of such work and
its impact on the remainder of the Project;
(7) Lien releases from each of Tenant's contractor(s) and
subcontractor(s) satisfactory to Landlord must be submitted to Landlord
within thirty (30) days after completion of the work performed by the
contractor(s) or subcontractor(s); and
(8) Tenant shall be solely responsible for the safety and
security of all equipment and property installed or placed in, on or
about the Premises by Tenant or any Tenant Party.
B. FINISH ALLOWANCE. Notwithstanding subparagraph 6A(1) above,
Landlord grants Tenant an allowance in the amount of $223,425 (the FINISH
ALLOWANCE) to be utilized by Tenant in performing alterations and improvements
to the Premises to "finish-out" the Premises. Any improvements or alterations
performed by Tenant and paid for out of the Finish Allowance, including
without limitation, any work related thereto such as design, engineering, and
construction management services, is referred to herein as the TENANT FINISH
WORK. Landlord will pay such invoices up to, but not in excess of, the Finish
Allowance conditioned upon:
(1) Tenant shall submit all invoices received in connection
with the Tenant Finish Work to Landlord for payment not less than fifteen
(15) days prior to the due date of such invoice. Landlord, at its option,
will not be obligated to pay any invoice not received by such date; and
(2) Landlord having reasonably satisfied itself that all
conditions/requirements set forth in subparagraph 6A above have been
satisfied; and
(3) Landlord having inspected and approved of the work for
which payment is sought, such approval not to be unreasonably withheld,
conditioned or delayed; and
(4) The Finish Allowance may not be used or allocated for any
materials or property, or for the labor incurred in constructing or
installing same, that would be characterized as Tenant's Property under
subparagraph 6C below, it being the intention of both parties hereto
that, without limiting subparagraph 6D below, all improvements and
alterations paid for with the Finish Allowance will in all events and
circumstances be Landlord's property.
Any decision to pay or not pay any invoice will be made within ten (10)
business days after receiving the subject invoice, provided, however, that
Landlord may further condition such approval upon the satisfaction of any of
the conditions/requirements of Paragraph 6A or this Paragraph 6B that may not
have been satisfied within such ten (10) day period (I.E., lien waivers).
Failure to disapprove of an invoice within such ten (10) day period shall
constitute approval thereof. All invoices will be paid within fifteen (15)
days after Landlord has approved the invoice and is satisfied that all
conditions and requirements set forth in Paragraph 6A and this Paragraph 6B
have been satisfied. All cost and expenses incurred by Tenant in making any
alterations or improvements to the Premises or the Project in excess of the
Finish Allowance will be Tenant's sole cost and expense. If the Finish
Allowance has not been fully utilized within one (1) year
COMMERCIAL LEASE AGREEMENT PAGE 5
after the Commencement Date, and provided that Tenant is not then in default
under this Lease, the remaining balance will be applied to Base Monthly Rent
and Adjustments until the Finish Allowance is exhausted. At the end of such
year, Landlord will provide Tenant with a written accounting of the balance,
if any, of the Finish Allowance.
C. TENANT'S PROPERTY. Tenant, at its own cost and expense, may
erect such shelves, racks, bins and trade fixtures (collectively, TENANT'S
PROPERTY) within the Premises as it desires and without Landlord's prior
consent provided that (a) such items do not alter the basic character of the
Premises or the Building; (b) such items do not overload or damage the
Premises or the Building or the utility or other systems serving same; (c)
such items may be removed without material injury to the Premises and the
Building; and (d) the construction, erection or installation thereof complies
with all Applicable Laws, applicable building permits and certificates of
occupancy; and (e) provided that Tenant's installation of Tenant's Property
prior to the Commencement Date will be subject to Paragraph 5B above. All of
Tenant's Property shall remain the property of Tenant and shall be removed on
or before the earlier to occur of the date of termination of this Lease or
Tenant's vacating of the Premises. Tenant shall promptly repair any damage to
the Project or the Premises caused by the removal of any of Tenant's Property.
Any of Tenant's Property not so removed and any other property of Tenant not
removed prior to the termination of this Lease or Tenant's vacating of the
Premises shall thereupon be conclusively presumed to have been abandoned by
Tenant, and Landlord may, at its option, take over possession of any and all
of the foregoing and either (i) declare the same to be the property of
Landlord by written notice to Tenant at the address provided herein or (ii) at
the sole cost and expense of Tenant, remove, store, and/or dispose of the same
or any part thereof, all at Tenant's cost, in any manner that Landlord shall
choose without incurring liability to Tenant or any other person.
D. LANDLORD'S PROPERTY/RESTORATION OF PREMISES BY TENANT. Except
as provided in Xxxxxxxxx 0X above, all alterations, additions, and
improvements made to, or fixtures or other improvements placed in or on, the
Premises, whether temporary or permanent in character are a part of the
Premises and are the property of Landlord when they are made to or placed in
or on the Premises, without compensation to Tenant; provided that, at
Landlord's option, upon the termination of this Lease, Landlord may require
Tenant, at Tenant's cost, to remove any improvements, other than the Tenant
Finish Work, made to the Premises or Project by Tenant and restore the
Premises to substantially the condition it was in upon the completion of the
Tenant Finish Work, reasonable wear and tear excepted; and further provided
that, if Tenant first properly requested and Landlord gave its consent to such
improvements, Landlord must make such election at the time of giving such
consent.
E. INDEMNITY. Tenant hereby indemnifies and holds Landlord
harmless from any claims, demands, actions, losses, and damages arising from
activities of Tenant or any Tenant Party, or any of their invitees, in
connection with any alterations, improvements or additions made or contracted
for by Tenant.
7. USE. Subject to Applicable Laws, the Premises shall be used only for
the purpose of general office, manufacturing, receiving, storing, shipping and
selling (other than retail) products, materials and merchandise made and/or
distributed by Tenant, and for such other lawful purposes as may be incidental
thereto. Provided that such use is permitted by Applicable Laws, any
manufacturing performed by Tenant at the Premises shall be limited to the
manufacture and/or assembly of pharmaceutical, diet supplement and/or other
human health related products. Outside storage, including without limitation,
storage of trucks and other vehicles, is prohibited without Landlord's prior
written consent. Tenant shall not permit any objectionable or unpleasant
odors, smoke, dust, gas, noise or vibrations to emanate from the Premises, nor
take any other action that would constitute a health or environmental hazard
or nuisance or that would disturb, interfere with, or endanger Landlord or the
occupant of any other land or buildings in the vicinity of the Project or any
other tenant of the Project. Tenant's use of the Premises must in any event
comply with all Applicable Laws including, without limitation, the Declaration
and Applicable Laws. TENANT SHALL MAKE ITS OWN DETERMINATIONS AS TO THE
SUITABILITY OF THE PREMISES FOR ITS INTENDED USE. BY ENTERING INTO THIS LEASE,
TENANT REPRESENTS AND WARRANTS THAT IT HAS INVESTIGATED AND SATISFIED ITSELF
AS TO WHETHER OR NOT APPLICABLE LAWS PERMIT ITS INTENDED USE OF THE PREMISES
AND THAT TENANT IS RELYING SOLELY UPON SUCH INVESTIGATIONS, AND NOT UPON AND
REPRESENTATIONS OF LANDLORD, IN ENTERING INTO THIS LEASE. If Tenant's
particular use of the Premises requires that additional improvements or
modifications be made to the Premises or the Project by Landlord so that the
Premises and the Project complies in all respects with Applicable Laws, Tenant
shall be solely responsible for such costs.
COMMERCIAL LEASE AGREEMENT PAGE 6
8. HAZARDOUS MATERIALS.
A. HAZARDOUS MATERIALS DEFINED. As used in this Lease, the term
HAZARDOUS MATERIALS means and includes (i) any hazardous, toxic or dangerous
waste, substance or material, as defined for purposes of the Comprehensive
Environmental Response Compensation and Liability Act of 1980, as amended, the
Resource Conservation and Recovery Act of 1976, as amended, or any other
Applicable Laws applicable to the Premises and establishing liability,
standards, or regulating or requiring action as to the industrial hygiene,
use, generation, treatment, discharge, spillage, storage, uncontrolled loss,
seepage, filtration, disposal, removal, or existence of a hazardous, toxic or
dangerous waste, substance or material (collectively, ENVIRONMENTAL LAWS) and
(ii) any waste, substance or material which, even if not so regulated, is
known to pose a hazard to the health and safety of persons or property,
specifically including, without limitation, oil and petroleum products and
by-products and asbestos.
B. PROHIBITION OF HAZARDOUS MATERIALS/TENANT'S LIABILITY. Except
for Hazardous Materials that are used only as an incidental part of Tenant's
day-to-day business operations and not as an integral part thereof (E.G., fuel
for forklifts and similar equipment, office supplies, cleaning solvents),
Tenant may not use, treat, handle, store, generate, dispose of or release or
cause or permit any Tenant Party, or any of their invitees, to use, handle,
store, generate, treat, dispose of or release, in, on, under or from the
Premises or the Project any Hazardous Materials. Without limiting any of the
above:
(1) Tenant covenants and agrees that it shall at its own
expense procure, maintain in effect and comply with all conditions of any
and all permits, licenses and other governmental and regulatory approvals
required for Tenant's use of the Premises and any operations or conduct
of Tenant involving the use, handling, generation, treatment, storage,
disposal, management or release of any Hazardous Materials. Tenant shall
cause any and all Hazardous Materials that are to be removed from the
Premises to be transported solely by duly licensed haulers and to duly
licensed facilities for final disposal of such Hazardous Materials.
Tenant shall in all respects, handle, treat, deal with and manage any
and all Hazardous Materials in, on, under or about the Premises as a
result of the actions, conduct or any part of the business operations of
Tenant or any Tenant Party, or any of their invitees, in complete
conformity with all Applicable Laws and prudent industry practices
regarding the management of such Hazardous Materials. All reporting
obligations relating to Hazardous Materials in, on, under or about the
Premises as a result of the actions, conduct or any part of the business
operations of Tenant or any Tenant Party, or any of their invitees, are
solely the responsibility of Tenant. Upon expiration or earlier
termination of this Lease, Tenant covenants and agrees to cause all
Hazardous Materials existing in, on, or under the Premises to be removed
from the Premises and transported for use, storage or disposal in
accordance and in compliance with all Applicable Laws. In addition, and
unless Landlord instructs Tenant otherwise, at the expiration of the term
of this Lease, Tenant shall remove all tanks or fixtures which were
placed on the Premises by or on behalf of Tenant or any Tenant Party
during the term of this Lease and which contain, have contained or are
contaminated with, Hazardous Materials;
(2) Tenant shall immediately notify Landlord in writing
of (i) any Tenant Release (hereinafter defined), (ii) any enforcement,
clean-up, removal or other governmental or regulatory action instituted,
completed or threatened against Tenant, the Premises, the Project, or any
part thereof pursuant to any Applicable Laws; (iii) any claim made or
threatened by any person against Tenant, Landlord, the Premises, or the
Project relating to damage, contribution, cost recovery, compensation,
loss or injury resulting from or claimed to result from any Hazardous
Materials, and (iv) any reports made to any environmental agency arising
out of or in connection with any Hazardous Materials in, on or about or
under the Premises or with respect to any Hazardous Materials removed
from the Premises, including, any complaints, notices, warnings, reports
or asserted violations in connection therewith. Tenant shall also provide
to Landlord, as promptly, as possible, and in any event within five (5)
business days after Tenant first received or sent the same, with copies
of all claims, reports, complaints, notices, warnings or asserted
violations relating in any way to the Premises or Tenant's use thereof.
Tenant shall not take any remedial action in response to the presence of
any Hazardous Materials in/on, about or under the Premises, nor enter
into any settlement agreement, consent, decree or other compromise in
respect to any claims relating to or in any way connected with the
Premises without first notifying Landlord of Tenant's intention to do so
and affording Landlord ample opportunity to appear, intervene or
otherwise appropriately assert and protect Landlord's interest with
respect thereto;
COMMERCIAL LEASE AGREEMENT PAGE 7
(3) Tenant shall indemnify, at Landlord's option, defend
(with counsel reasonably acceptable to Landlord), protect and hold
Landlord and each of Landlord's officers, directors, partners, employees,
agents, attorneys, successors and assigns free and harmless from and
against any and all claims, liabilities, damages, costs, penalties,
forfeitures, losses or expenses (including attorneys' fees) for death or
injury to any person or damage to any property whatsoever (including
water tables and atmosphere) arising or resulting in whole or in part,
directly or indirectly, from the presence, release or discharge of
Hazardous Materials in, on, under, upon or from the Premises to the
extent that such presence, release or discharge was caused or permitted
by Tenant or any Tenant Party, or any of their invitees, or from the
transportation or disposal of Hazardous Materials to or from the Premises
or the Project by Tenant or any Tenant Party, or any of their invitees
(herein, a TENANT RELEASE). Tenant's obligations hereunder shall
include, without limitation, and whether foreseeable or unforeseeable,
all costs of any required or necessary repairs, clean-up or
detoxification or decontamination of the Premises or the Project and any
other land contaminated or adversely effected by the Tenant Release and
the presence and implementation of any closure, remedial action or other
required plans in connection therewith, and shall survive the expiration
of or early termination of this Lease;
(4) Landlord may at any time commission an environmental
audit of the Premises or the Project. If it is determined that a Tenant
Release has in fact occurred, then, without limitation of any other remedy
Landlord may have hereunder, Tenant shall reimburse the actual costs of the
testing to Landlord on demand as additional Rent.
(5) Tenant shall execute affidavits, representations, and
the like from time to time at Landlord's request concerning Tenant's
actual knowledge and belief regarding the presence of Hazardous Materials
in, on or under the Premises.
C. ENVIRONMENTAL STUDIES. Landlord represents that, except as set
forth in any written studies or reports provided to Tenant, Landlord has no
actual knowledge of any adverse environmental conditions affecting the Land;
provided. however, that Landlord makes no representations or warranties
regarding the truth or accuracy of the environmental reports so provided and
Tenant shall rely upon such reports, if at all, at Tenant's sole risk.
D. SURVIVAL. The respective covenants, rights and obligations of
Landlord and Tenant under this Paragraph 8 shall survive the expiration or
earlier termination of this Lease.
9. SIGNAGE. Any signage Tenant desires for the Premises shall be
subject to Landlord's written approval and shall be submitted to Landlord for
approval prior to the Commencement Date of this Lease. Tenant shall repair,
paint and/or replace the building facia surface to which its signs are
attached upon vacation of the Premises, or the removal or alteration of its
signage. Tenant shall not (i) make any changes to the exterior of the
Building, (ii) install any exterior lights, decorations, balloons, flags,
pennants, banners or painting, or (iii) erect or install any signs, windows or
door lettering, placards, decorations or advertising media of any type which
can be viewed from the exterior of the Building, without Landlord's prior
written consent. All signs, decorations, advertising media, blinds, draperies
and other window treatment or bars or other security installations visible
from outside the Building shall conform in all respects to the criteria
established by Landlord and Applicable Laws.
10. TAXES.
A. REAL PROPERTY TAXES. Subject to reimbursement by Tenant as
provided in Paragraph 4B above, Landlord shall pay all taxes, assessments and
governmental charges of any kind and nature and all assessments due to deed
restrictions and/or owner or community associations (collectively referred to
herein as REAL PROPERTY TAXES), that accrue against the Project, or any part
thereof. If at any time during the term of this Lease, there shall be levied,
assessed or unposed on Landlord a capital levy or other tax directly on the
Rent received under this Lease and/or a franchise tax, gross receipts tax (but
not a typical or customary state or federal income tax), assessment, levy or
charge measured by or based, in whole or in part, upon Rent paid under this
Lease, then all such taxes, assessments, levies or charges, or the part
thereof so measured or based, shall be deemed to be included within the term
REAL PROPERTY TAXES for the purposes hereof. Landlord shall have the right to
employ a tax consulting firm to attempt to assure a fair tax burden on the
Project and the Premises within the applicable taxing jurisdiction. Tenant
agrees to pay its Proportionate
COMMERCIAL LEASE AGREEMENT PAGE 8
Share of the cost of such consultant as additional Rent.
B. PERSONAL PROPERTY TAXES. Tenant shall be liable for all taxes
levied or assessed against Tenant's Property and any other personal property
or fixtures placed or installed in the Premises or the Project by or on behalf
of Tenant. If any such taxes are levied or assessed against Landlord or
Landlord's property and (i) Landlord pays the same, or (ii) the assessed value
of Landlord's property is increased by inclusion of such personal property and
fixtures and Landlord pays the increased taxes, then, Tenant shall pay to
Landlord such taxes within ten (10) days after demand. If Tenant later
contests such taxes and is successful in abating or reducing all or a portion
of same, and provided that Tenant has, in fact, reimbursed Landlord for the
taxes paid by Landlord, Landlord will return to Tenant the amount by which
such taxes were reduced or abated, up to the amount Tenant reimbursed Landlord.
11. UTILITIES. Landlord agrees to provide water, sewer and gas utility
lines to the outside of the exterior walls of the Building and electricity
service to be provided to a transformer located at the Project. Tenant shall
pay for all utilities servicing the Premises, including, without limitation
water, gas, heat, light, power, telephone, sewer, sprinkler charges and other
utilities and services used on or at the Premises, together with any taxes,
penalties, surcharges or the like pertaining to the Tenant's use of the
Premises, and any maintenance charges for utilities. Tenant shall pay its
Proportionate Share of all charges for jointly metered and common area
utilities as additional Rent. Landlord shall not be liable for any
interruption or failure of utility service at the Premises and all Rent owed
pursuant to the terms of this Lease shall continue to be due notwithstanding
such interruption.
12. REPAIRS AND MAINTENANCE.
A. LANDLORD'S OBLIGATION TO REPAIR AND MAINTAIN.
(1) Landlord, at its own cost and expense, shall maintain
the structural soundness of the Building's roof, foundation and exterior
walls in good repair, except for reasonable wear and tear and except for
damage caused by any act or omission of Tenant or any Tenant Party or
their invitees. Landlord may elect to repair any damage caused by Tenant
or any Tenant Party or their invitees, and if Landlord so elects, Tenant
shall pay Landlord the cost or anticipated cost of such repair on demand,
subject to Paragraph 13C hereof. The term WALLS as used herein shall not
include windows, glass or plate glass, doors, special store fronts or
office entries. Tenant shall promptly give Landlord written notice of any
defect or need for repairs, after which Landlord shall have reasonable
opportunity to repair same or cure such defect.
(2) Landlord shall maintain or cause to be maintained all
exterior painting, parking areas (inclusive of striping) and landscaped
areas of the Project and utility lines outside the exterior walls of the
Building in good condition and repair, other than those areas that are
expressly Tenant's obligations under Paragraph 12B below. Tenant shall
reimburse Landlord for Tenant's Proportionate Share of any costs incurred
by Landlord under this paragraph, net of the Adjustments being escrowed
monthly for maintenance under Paragraph 4B above. Notwithstanding any of
the above, if it is determined that any specific repair or maintenance
otherwise required to be performed by Landlord under this subparagraph is
caused solely by Tenant, any Tenant Party or any of their invitees,
Tenant shall be solely responsible for the cost of such repair or
maintenance and such shall be paid to Landlord outside of and in addition
to the Adjustments. All such amounts payable under this subparagraph
shall be owed to Landlord as additional Rent.
(3) In the event the Building or the Premises is damaged
or becomes out of repair and such is the obligation of Landlord to repair
or maintain hereunder, Tenant shall provided prompt written notice to
Landlord thereof stating the nature of the needed repairs. Landlord will
then have thirty (30) days to make any necessary repairs or such longer
time as is reasonably necessary with the exercise of due diligence if
such repairs cannot reasonably be completed in thirty (30) days.
Additionally, in the event of an emergency, defined for purposes of this
subparagraph as a condition that if allowed to continue to exist without
repair would result in damage, injury or death to property or person, and
assuming that it is not reasonably feasible for Tenant to give the
required notice to Landlord, then Tenant may make such repairs as are
reasonably necessary to prevent further immediate damage or injury to
person or property; provided that Tenant gives Landlord prompt written
notice of the nature of the emergency and the action taken by Tenant. In
such event, Landlord shall reimburse
COMMERCIAL LEASE AGREEMENT PAGE 9
Tenant within thirty (30) days of invoice for the actual costs of such
repairs made by Tenant.
B. TENANT'S OBLIGATION TO REPAIR AND MAINTAIN. Except only for
maintenance, repair and replacement performed by Landlord pursuant to
Paragraph 12A hereof, Tenant, at its own cost and expense, shall maintain in
good condition and promptly make all necessary repairs and replacements to
(i) all parts of the Premises, (ii) all utility lines and appurtenances from
the exterior walls of the Building to and within the Premises, and (iii) any
and all overhead doors, loading docks, loading dock levelers and loading
dock equipment. Additionally, Tenant shall maintain the walkways, parking
areas and facilities, driveways and alleys located within the Adjacent Area,
as illustrated on EXHIBIT "C" attached hereto, in a reasonably clean and
sanitary condition. Tenant, at its own cost and expense, shall enter into a
regularly scheduled preventive maintenance/service contract with a
maintenance contractor approved by Landlord for servicing all hot water,
heating and air conditioning systems and equipment within the Premises; which
service contract must include all services suggested by the equipment
manufacturer in its operations/maintenance manual and must become effective
within thirty (30) days of the date Tenant takes possession of the Premises.
Landlord reserves the right to perform any of Tenant's obligations set
forth under this paragraph including utility line maintenance and any other
items that are otherwise Tenant's obligations under this paragraph to the
extent that Tenant fails to perform its obligations thereunder within the
time frames set forth in Paragraph 18F. In such event, Landlord shall be
entitled to an administrative fee of ten percent (10%) of the costs and
expense of all of the foregoing, and Tenant shall be liable for the cost and
expense of such repair, replacement, maintenance and other such items, as
well as the administrative fee.
13. INSURANCE.
A. LANDLORD'S INSURANCE. Landlord shall maintain insurance
covering the Building (except that Landlord shall not be required to insure
any part of the partitions, fixtures, additions and other improvements that
may have been constructed, erected or installed in or about the Premises or
for the benefit of, or by or for Tenant, including, without limitation, the
Tenant Finish Work) in an amount not less than one hundred percent (100%) of
the replacement cost thereof insuring against the perils of Fire, Lightning,
Extended Coverage, Vandalism and Malicious Mischief (collectively, LANDLORD'S
INSURANCE).
B. TENANT'S INSURANCE. Tenant, at its own expense, shall maintain
during the term of this Lease a policy or policies of worker's compensation
(or its equivalent provided such is approved by Landlord, such not to be
unreasonably withheld) and commercial general liability insurance, including
personal injury and property damage, with contractual liability endorsement,
in the amount of Five Hundred Thousand Dollars ($500,000.00) for property
damages and One Million Dollars ($1,000,000.00) per occurrence for personal
injuries or deaths of persons occurring in or about the Premises and the
Project; provided, such limits may be adjusted upward in Landlord's
reasonable discretion based upon inflation or upon the type of business
conducted by Tenant in the Premises. Said policies shall (i) name Landlord as
an additional insured and insure Landlord's contingent liability under this
Lease (except for the worker's compensation policy, which instead shall
include waiver of subrogation endorsement in favor of Landlord), (ii) be
issued on an occurrence (not claims made) basis, (iii) be issued by an
insurance company which is acceptable to Landlord, and (iv) provide that said
insurance shall not be cancelled unless thirty (30) days prior written notice
shall have been given to Landlord. In addition to the above, Tenant shall
maintain insurance insuring the interest of Tenant and covering all of
Tenant's property and all partitions, fixtures, additions and other
improvements that may have been constructed, erected or installed in or about
the Premises or for the benefit of, or by or for Tenant, inclusive of the
Tenant Finish Work, and covering all contents of the Premises, in an amount
not less than one hundred percent (100%) of the replacement cost thereof
insuring against the perils of Fire, Lightning, Extended Coverage, Vandalism
and Malicious Mischief. Said policy or policies or certificates thereof shall
be delivered to Landlord by Tenant upon commencement of the term of the Lease
and at least thirty (30) days prior to the effective date of each renewal of
said insurance.
Tenant will not permit the Premises to be used for any purpose or in any
manner that would (i) void the insurance thereon, (ii) increase the insurance
risk, or (iii) cause the disallowance of any sprinkler credits, including
without limitation, use of the Premises for the receipt, storage or handling
of any product, material or merchandise that is explosive or highly
inflammable. If any increase in the cost of any insurance on the Premises or
the Building is caused by Tenant's use of the Premises, or because Tenant
vacates the Premises, then Tenant shall pay the amount of such
COMMERCIAL LEASE AGREEMENT PAGE 10
increase to Landlord upon demand.
C. WAIVER OF SUBROGATION. NOTWITHSTANDING ANY OTHER PROVISION OF
THIS LEASE, LANDLORD AND TENANT HEREBY WAIVE ANY RIGHTS EACH MAY HAVE AGAINST
THE OTHER ON ACCOUNT OF ANY LOSS OR DAMAGE OCCASIONED TO LANDLORD OR TENANT,
AS THE CASE MAY BE (WHETHER OR NOT SUCH LOSS OR DAMAGE IS CAUSED BY THE FAULT
OR SOLE OR CONCURRENT NEGLIGENCE OF, WITH RESPECT TO LOSS OR DAMAGE TO THE
PROPERTY OF TENANT, LANDLORD OR ANY LANDLORD PARTY, OR, WITH RESPECT TO ANY
LOSS OF DAMAGE TO ANY PROPERTY OF LANDLORD, OF TENANT, ANY TENANT PARTY OR
ANY OF THEIR INVITEES), TO THEIR RESPECTIVE PROPERTY, THE PREMISES, ITS
CONTENTS OR TO ANY OTHER PORTION OF THE BUILDING OR THE PROJECT ARISING FROM
ANY RISK THAT WOULD BE COVERED BY ANY INSURANCE REQUIRED TO BE CARRIED UNDER
THIS LEASE (WHETHER OR SUCH INSURANCE IS ACTUALLY CARRIED OR MAINTAINED), OR
OTHERWISE CARRIED BY THE WAIVING PARTY (BUT, AS TO ANY SUCH INSURANCE
OTHERWISE CARRIED, ONLY TO THE EXTENT OF SUCH INSURANCE PROCEEDS ACTUALLY
RECOVERED). THE PARTIES HERETO EACH, ON BEHALF OF THEIR RESPECTIVE INSURANCE
COMPANIES INSURING THE PROPERTY OF EITHER LANDLORD OR TENANT AGAINST ANY SUCH
LOSS, WAIVE ANY RIGHT OF SUBROGATION THAT IT MAY HAVE AGAINST LANDLORD OR
TENANT, AS THE CASE MAY BE. EACH PARTY TO THIS LEASE AGREES IMMEDIATELY TO
GIVE TO EACH SUCH INSURANCE COMPANY WRITTEN NOTIFICATION OF THE TERMS OF THE
MUTUAL WAIVERS CONTAINED IN THIS PARAGRAPH, AND TO HAVE SAID INSURANCE
POLICIES PROPERLY ENDORSED, IF NECESSARY, TO PREVENT THE INVALIDATION OF SAID
INSURANCE COVERAGES BY REASON OF SAID WAIVERS.
14. LIABILITY/INDEMNIFICATION.
A. LANDLORD'S LIABILITY AND INDEMNITY.
(1) RELEASE FROM LIABILITY. Except as otherwise
expressly provided in this Lease, neither Landlord nor any Landlord
Party (hereinafter defined) will be liable to Tenant or any Tenant Party
or any of their invitees for any death or injury to person or damage to
property on or about the Premises or the Project caused by or arising
out of, in whole or in part, (i) the negligence of, or act or omission
of, Tenant or any Tenant Party or any of their invitees, (ii) the
Premises or the Project becoming out of repair, (iii) the leakage of
gas, oil, water or steam or by electricity emanating from any part of
the Premises or the Project, or (iv) any other cause, unless and then
only to the extent such death or injury to person or damage to property
is due to the negligence or willful misconduct of Landlord or any
Landlord Party. As used in this Paragraph 14, a LANDLORD PARTY shall
mean one or more of Landlord's officers, partners, shareholders,
employees, agents or contractors.
(2) LANDLORD'S INDEMNITY OF TENANT. Except for any
claims, rights of recovery and causes of action that Tenant has
expressly herein waived or released or for which Landlord is not
responsible hereunder, Landlord shall indemnify and hold Tenant and each
Tenant Party harmless from and against any and all fines, suits, losses,
costs, liabilities, claims, demands, actions and judgments of every kind
and character, including reasonable court costs and attorneys fees,
suffered by, recovered from, or asserted against Tenant or any Tenant
Party for any injury or death to any person or damage to any property
in, on, or about the Premises or the Project to the extent, and only to
the extent, that such death or injury to person or damage to property is
caused by the negligence or willful misconduct of Landlord or any
Landlord Party. Upon the occurrence of an event which Landlord is
required to indemnify Tenant against, and upon demand by Tenant,
Landlord shall employ counsel reasonably acceptable to Tenant and defend
Tenant against any liability for such event, all at Landlord's cost.
B. TENANT'S INDEMNITY. Except for any claims, rights of recovery
and causes of action that Landlord has expressly herein waived or released or
for which Tenant is not responsible hereunder, Tenant shall indemnify and
hold Landlord and each Landlord Party harmless from and against any and all
fines, suits, losses, costs, liabilities, claims, demands, actions and
judgments of every kind and character, including reasonable court costs and
attorneys fees, suffered by, recovered from, or asserted against Landlord or
any Landlord Party (i) arising by reason of any breach, violation or
COMMERCIAL LEASE AGREEMENT PAGE 11
non-performance by Tenant of any term, provision, covenant, condition or
agreement to be performed or abided by Tenant hereunder, (ii) arising on
account of death, injury or damage to person or property in, on, or about the
Premises or the Project when such death, injury or damage is caused or arises
out of the negligence or willful misconduct of Tenant, any Tenant Party or
any of their invitees, and (iii) with respect to any action brought by a
Tenant Party or any invitee of Tenant or any Tenant Party, arising out of any
matter for which neither Landlord nor any Landlord Party is liable or
responsible hereunder. Upon the occurrence of an event which Tenant is
required to indemnify Landlord or a Landlord Party against, and upon demand
by Landlord, Tenant shall employ counsel reasonably acceptable to Landlord
and defend Landlord or such Landlord Party against any liability for such
event, all at Tenant's cost.
C. LIABILITY FOR ACTS OF TENANT AND LANDLORD PARTIES. The
individual(s) executing this Lease on behalf of Landlord or Tenant, as
applicable, are doing so in their representative capacity only, solely as a
representative of Landlord or Tenant, as applicable, and any liability to
Landlord or any Landlord Party or Tenant or any Tenant Party arising or
resulting hereunder based upon the actions of such individual(s) or any other
Landlord Party or Tenant Party, as applicable, shall merely be that of
Landlord (as to any Landlord Party) or Tenant (as to any Tenant Party) and
not such individual(s) or Landlord Party or Tenant Party.
D. SURVIVAL. The releases, indemnities and covenants of Landlord
and Tenant in this Paragraph 14 are in addition to, and not in limitation of,
any other indemnities made by Landlord or Tenant elsewhere in this Lease. The
provisions of this Section 14 shall survive the expiration or termination of
this Lease with respect to any claims or liability arising out of events
occurring prior to such expiration or termination.
15. CASUALTY.
A. TERMINATION OF LEASE. If the Premises should be damaged or
destroyed by fire or other peril, Tenant immediately shall give written
notice to Landlord. If: (i) the Building should be totally destroyed by any
peril not covered by the insurance to be provided by Landlord under Paragraph
13A above; or if (ii) the Premises should be so damaged thereby that, in
Landlord's estimation, rebuilding or repairs cannot be completed within one
hundred eighty (180) days after the date of such damage; or if (iii) the
Premises should be so damaged thereby that, in Landlord's estimation,
rebuilding or repairs of the portion thereof required to be insured by
Landlord can be substantially completed within one hundred eighty (180) days
after the date of such damage, but the insurance proceeds available to
Landlord will not, in Landlord's estimation, be sufficient to complete such
rebuilding or repairs (due to such insurance proceeds being applied to
mortgage debt or otherwise) and Landlord is either unable or unwilling to
advance sufficient funds to complete such rebuilding or repairs; then in any
of such events this Lease shall cease and terminate as if and to the extent
the effective date of such termination had been the date originally scheduled
for the expiration of the term of this Lease, and the Rent shall be abated
during the previously unexpired term of this Lease, effective upon the date
of the occurrence of such damage. Landlord's determinations under this
paragraph must be made in writing to Tenant within forty-five (45) days after
the subject casualty.
B. RESTORATION OF PREMISES BY LANDLORD. Subject to the provisions
of Section 15.A above, if the Premises should be damaged by any peril covered
by the insurance to be provided by Landlord under Paragraph 13A above, and in
Landlord's estimation, rebuilding or repairs of the portion thereof required
to be insured by Landlord can be substantially completed within one hundred
eighty (180) days after the date of such damage, this Lease shall not
terminate, and Landlord shall restore the Premises to substantially its
previous condition, except that Landlord shall not be required to rebuild,
repair or replace any part of the partitions, fixtures, additions and other
improvements that may have been constructed, erected or installed in, or
about the Premises or for the benefit of, or by or for Tenant. During any
period of rebuilding, repair and restoration, Landlord shall allow Tenant a
reasonable reduction in Rent based upon, among other things, the adverse
effect such casualty and restoration have on Tenant's business operations.
Subject to Force Majeure, if such repairs and rebuilding of the Premises have
not been substantially completed within one hundred eighty (180) days after
the date of such damage, Tenant, as Tenant's exclusive remedy, may give
Landlord notice of Tenant's intention to terminate the Lease effective as of
the date specified in such notice, which date shall be not less that thirty
(30) days after the notice. If the repairs and rebuilding have not been
substantially completed by the date specified in such notice, Tenant, as
Tenant's exclusive remedy, may immediately terminate this Lease by delivering
written notice of termination to Landlord, in which event the rights and
obligations hereunder shall cease and terminate as if and to the extent the
effective date of such termination had been the date originally scheduled for
the expiration of the term
COMMERCIAL LEASE AGREEMENT PAGE 12
of this Lease, and Rent shall be abated during the previously unexpired term
of this Lease, effective upon the date of the termination.
16. CONDEMNATION.
A. MATERIAL TAKING. If any portion of the Premises or the
Project is taken for any public or quasi-public use under governmental law,
ordinance or regulation, or by right of eminent domain, or by private
purchase in lieu thereof and the taking materially interferes with the use of
the Premises for the purpose for which they were leased to Tenant or causes
the Premises or the exclusive parking area designated for Tenant to be in
noncompliance with Applicable Laws, then within thirty (30) days after such
taking Landlord shall notify Tenant as to whether or not Landlord will
reconstitute the Premises or the Project such that the Premises or the
Project once again complies with Applicable Laws or replicate the Premises or
the Project to substantially the condition it was in prior to such taking, as
applicable, within one hundred eighty (180) days after such taking. If
Landlord notifies Tenant that it will not replicate or reconstitute the
Premises or the Project, as applicable, or otherwise fails to complete the
reconstitution or replication within one hundred eighty (180) days after such
taking, then this Lease shall terminate and the Rent shall be abated during
the unexpired portion of this Lease, effective as of the date of such taking.
If Landlord notifies Tenant that it will replicate or reconstitute the
Premises or the Project, as applicable, then this Lease shall not terminate
but Rent accruing after the date of such taking shall be reduced to such
extent as may be fair and reasonable under all of the circumstances (which
may include a abatement of all Rent), effective as of the date of such taking
until the Premises or the Project as applicable, is fully reconstituted or
replicated, at which time Rent will again adjust to the amounts set forth in
Paragraph 4.
B. OTHER TAKING. With respect to any taking not covered by
Paragraph 16A above, this Lease shall not terminate, but the Rent payable
hereunder during the unexpired portion of this Lease shall be reduced to such
extent as may be fair and reasonable under all of the circumstances,
effective as of the date of such taking.
C. CONDEMNATION PROCEEDS. All compensation awarded in connection
with or as a result of any eminent domain or condemnation proceedings shall
be the property of Landlord, and Tenant hereby assigns any interest in any
such award to Landlord; provided, however, Landlord shall have no interest in
any award made to Tenant for loss of business or goodwill or for the taking
of Tenant's fixtures and improvements, if a separate award for such items is
made to Tenant or reasonably allocable to Tenant for the taking of Tenant's
fixtures and improvements that Tenant would be permitted to remove upon
termination of this Lease.
17. ASSIGNMENT AND SUBLETTING.
A. PROHIBITION ON ASSIGNMENT AND SUBLETTING. Tenant shall not
have the right to assign, sublet, transfer or encumber this Lease, or any
interest therein, without the prior written consent of Landlord. Any
attempted assignment, subletting, transfer or encumbrance by Tenant in
violation of the terms and covenants of this paragraph shall be void. If
Tenant requests Landlord's consent to an assignment of this Lease or
subletting of all or a part of the Premises, it shall submit to Landlord, in
writing, the name of the proposed assignee or subtenant, the commencement
date of such assignment or subletting, the nature and character of the
business of the proposed assignee or subtenant and the proposed rates, terms
and other pertinent conditions of such assignment or subletting. Upon receipt
of a request for consent to an assignment or subletting, and unless such
request pertains to an assignment or sublease governed by Paragraph 17B
below, Landlord shall have the option (to be exercised within thirty (30)
days from the submission of Tenant's written request) to (i) cancel this
Lease (or the applicable portion thereof as to a partial subletting) as of
the commencement date stated in the above-mentioned notice of subletting or
assignment, unless Tenant withdraws the proposal to sublet or assign within
ten (10) days after Landlord's notice of cancellation is given, (ii) permit
such assignment or subletting, or (iii) reasonably withhold its consent to
such assignment or subletting. If Landlord elects to cancel this Lease and
Tenant does not withdraw the proposal to sublet or assign, then the term of
this Lease (as to the applicable portion of the Premises), and the tenancy
and occupancy of the applicable portion of the Premises by Tenant hereunder,
shall cease, terminate, expire, and come to an end as if the cancellation
date was the original termination date of this Lease with respect to the
applicable portion of the Premises. In the event Landlord consents to a
proposed assignment or subletting and the rent due and payable by any such
assignee or sublessee under any such permitted assignment or sublease (or a
combination of the rent payable under such assignment or sublease plus any
bonus or any
COMMERCIAL LEASE AGREEMENT PAGE 13
other consideration therefor or any payment, incident thereto) exceeds the
Base Monthly Rent payable under Paragraph 3 of this Lease for the applicable
space, net of Tenant's actual reasonable costs incurred in connection with
such assignment or subletting (E.G., attorneys' fees, marketing costs (but
not Tenant's internal costs)) and net of any finish out allowance granted by
Tenant in connection with any assignment or sublease not in excess of market
(E.G., Tenant may not recover any finish out allowance in excess of that
which would granted to a similarly situated tenant for similar space in
similar properties in the Dallas/Fort Worth area), Tenant shall pay to
Landlord all such excess rent and other excess consideration within ten (10)
days following receipt thereof by Tenant, whether or not such assignment or
subletting pertains to an assignment or subletting permitted under Paragraph
17B below.
B. PERMITTED ASSIGNMENTS/SUBLEASES. Notwithstanding the
provisions of Paragraph 17A, Tenant may, without the consent of Landlord, at
any time assign or otherwise transfer this Lease or any portion thereof to
any Affiliate (hereinafter defined); or any Corporation resulting from the
consolidation or merger of Tenant into or with any other entity; or to any
person, firm, entity or corporation acquiring a majority of Tenant's issued
and outstanding capital stock or substantially all of Tenant's assets. As
used herein, the term AFFILIATE shall mean a person or entity, corporate or
otherwise, that directly or indirectly through one or more intermediaries,
controls or is controlled by, or is under common control with Tenant. The
term CONTROL means the right and power, direct or indirect, to direct or
cause the direction of the management and policies of a person or business
entity, corporation or otherwise, through ownership or voting securities, by
contract or otherwise; provided, however, that in the event of an assignment,
the assignee shall assume in writing the terms and conditions set forth
herein to be observed and performed by the Tenant in a form reasonably
approved by Landlord. A sublease or assignment pursuant to this Paragraph 17B
shall not be subject to Landlord's recapture rights set forth in Paragraph
17A above.
C. ASSIGNMENTS IN BANKRUPTCY.
(1) If this Lease is assigned to any person or entity
pursuant to the provisions of the Bankruptcy Code, 11 U.S.C. Section 101
et. seq. (the BANKRUPTCY CODE), any and all monies or other
consideration payable or otherwise to be delivered in connection with
such assignment shall be paid or delivered to Landlord, shall be and
remain the exclusive property of Landlord and shall not constitute
property of Tenant or of the estate of Tenant within the meaning of the
Bankruptcy Code. Any and all monies or other considerations constituting
Landlord's property under the preceding sentence not paid or delivered
to Landlord shall be held in trust for the benefit of Landlord and be
promptly paid or delivered to Landlord.
(2) Any person or entity to which this Lease is assigned
pursuant to the provisions of the Bankruptcy Code, shall be deemed,
without further act or deed, to have assumed all of the obligations
arising under this Lease on and after the date of such assignment. Any
such assignee shall upon demand execute and deliver to Landlord an
instrument confirming such assumption.
D. EFFECT OF ASSIGNMENT. Any assignee, sublessee or transferee of
Tenant's interest in this Lease (all such assignees, sublessees and
transferees being hereinafter referred to as TRANSFEREES), by assuming
Tenant's obligations hereunder, shall assume liability to Landlord for all
amounts paid to persons other than Landlord by such Transferees in
contravention of this Paragraph 17. No assignment, subletting or other
transfer, whether consented to by Landlord or not or permitted hereunder
shall relieve the Tenant named herein of any liability hereunder for the
obligations of the "Tenant". If an event of default occurs while the Premises
or any part thereof are assigned or sublet, then Landlord, in addition to any
other remedies herein provided, or provided by law, may collect directly from
such Transferee all rents payable to the Tenant and apply such rent against
any sum due Landlord hereunder. No such collection shall be construed to
constitute a novation or a release of Tenant from the further performance of
Tenant's obligations hereunder.
18. DEFAULT BY TENANT. The following events (herein individually
referred to as EVENT OF DEFAULT) each shall be deemed to be events of default
by Tenant under this Lease:
A. Tenant shall fail to pay any installment of the Rent herein
reserved when due, or any other payment or reimbursement to Landlord required
herein when due, and such failure shall continue for a period of ten (10) days
after receipt of written notice from Landlord; provided, however, that an
event of default will occur without any
COMMERCIAL LEASE AGREEMENT PAGE 14
obligation of Landlord to deliver any notice if Landlord has given Tenant
written notice under this Paragraph 18A on two (2) or more occasions during
the twelve (12) month period preceding the current failure by Tenant to
timely pay Rent (though Tenant in such instances is granted a five (5) day
grace period from the date upon which the subject payment was due).
B. Tenant or any guarantor of the Tenant's obligations hereunder
shall (i) become insolvent; (ii) admit in writing its inability to pay its
debts; (iii) make a general assignment for the benefit of creditors; (iv)
commence any case, proceeding or other action seeking to have an order for
relief entered on its behalf as a debtor or to adjudicate it a bankrupt or
insolvent, or seeking reorganization, arrangement, adjustment, liquidation,
dissolution or composition of it or its debts under any law relating to
bankruptcy, insolvency, reorganization or relief of debtors or seeking
appointment of a receiver, trustee, custodian or other similar official for
it or for all or of any substantial part of its property; or (v) take any
action to authorize or in contemplation of any of the actions set forth above
in this paragraph.
C. Any case, proceeding or other action against the Tenant or any
guarantor of the Tenant's obligations hereunder shall be commenced seeking
(i) to have an order for relief entered against it as debtor or to adjudicate
it a bankrupt or insolvent; (ii) reorganization, arrangement, adjustment,
liquidation, dissolution or composition of it or its debts under any law
relating to bankruptcy, insolvency, reorganization or relief of debtors;
(iii) appointment of a receiver, trustee, custodian or other similar official
for it or for all or any substantial part of its property, and such case,
proceeding or other action (a) results in the entry of an order for relief
against it which it is not fully stayed within seven (7) business days after
the entry thereof or (b) shall remain undismissed for a period of forty-five
(45) days.
D. OMITTED.
E. Tenant shall fail to discharge any lien placed upon the
Premises or the Project in violation of Paragraph 28 hereof within sixty (60)
days after any such lien or encumbrance is filed against the Premises or the
Project; provided, however, that if Tenant in good faith disputes such lien,
Tenant may contest the lien without being in default hereunder provided that
Tenant bonds the lien to Landlord's reasonable satisfaction and the lien is
in any event removed or extinguished no later than one hundred and twenty
(120) days after filing.
F. Tenant shall fail to comply with any other terms in this Lease
other than those for which an event of default has been described in this
Paragraph 18, and such failure is not cured within thirty (30) days after
written notice thereof to Tenant, such notice to specify the nature of the
default and the action required to cure same, or if such failure cannot
reasonably be cured in thirty (30) days, such time as is reasonable under the
circumstances, not to exceed ninety (90) days, and provided that Tenant must
diligently proceed to cure the default.
19. LANDLORD'S REMEDIES. Upon the occurrence of any event of default
specified in this Lease, Landlord, at its option, may exercise one (1) or
more of the following remedies, in addition to all other rights and remedies
provided at law or in equity.
A. Landlord may, without judicial process, terminate this Lease
(whereupon all obligations and liabilities of Landlord hereunder shall
terminate) and without further notice repossess the Premises without having
any liability therefor (including specifically any liability or duty under
Section 93.002 of the Texas Property Code which is specifically superseded by
this Paragraph 19A) and be entitled to recover all loss and damage Landlord
may suffer by reason of such termination, whether through inability to relet
the Premises on satisfactory terms or otherwise, including without
limitation, accrued Rent and interest thereon, accrued late charges and
interest thereon, the unamortized cost of the Tenant Finish Work made at
Landlord's expense pursuant to Paragraph 2 hereof or otherwise, broker's fees
and commissions, attorneys' fees, moving allowance and any other costs
incurred by Landlord in connection with making or executing this Lease, the
cost of recovering the Premises and the costs of reletting the Premises
(including without limitation advertising costs, brokerage fees, leasing
commissions, reasonable attorneys' fees and refurbishing costs). If such
termination is caused by the failure to pay Rent, Landlord may elect, by
sending written notice thereof to Tenant, to receive liquidated damages in an
amount equal to the product of (i) the sum of the all Rent and other charges
payable hereunder for the month during which this Lease is terminated
multiplied by (ii) the lesser of (x) the product of sixty percent (60%)
multiplied by the number of full calendar months which would have remained in
the term of this Lease but for such termination or (y) twenty-four (24). Such
liquidated damages shall be in lieu of the payment of loss and
COMMERCIAL LEASE AGREEMENT PAGE 15
damage accruing after the date of such termination, but shall not be in lieu
of or reduce in any way any amounts or damages payable by Tenant to Landlord
and accruing prior to the date of termination, which for all purpose shall
include, but not be limited to, accrued Rent and interest thereon, late
charges and interest thereon the unamortized cost of the Tenant Finish Work,
broker's fees and commissions, attorneys' fees, any moving allowances and any
other costs incurred by Landlord in connection with making or executing this
Lease. Nothing contained in this Lease shall limit or prejudice the right of
Landlord to prove for and obtain in proceedings for bankruptcy or insolvency
by reason of the termination of this Lease, an amount equal to the maximum
allowed by any statute or rule of law in effect at the time when, and
governing the proceedings in which, the damages are to be proved, whether the
amount be greater, equal to, or less than the amount of the loss or damages
referred to above.
B. Landlord may, without judicial process, immediately terminate
Tenant's right of possession of the Premises by delivering to Tenant written
notice of such termination (whereupon all obligations and liability of
Landlord hereunder shall terminate), but not terminate this Lease, and,
without notice or demand, enter upon the Premises or any part thereof and
take absolute possession of the same, expel or remove Tenant and any other
person or entity who may be occupying the Premises, by force if necessary,
change the locks, without having any liability therefor (including
specifically any liability or duty under Section 93.002 of the Texas Property
Code which is specifically superseded by this Xxxxxxxxx 00X) and at
Landlord's option, Landlord may relet the Premises or any part thereof for
such terms and such rents as Landlord may in its sole discretion elect. In
the event of a termination of Tenant's possession of the Premises under this
Part B and notwithstanding anything in Section 93.002 of the Texas Property
Code to the contrary, Landlord shall have no obligation whatsoever to tender
to Tenant a key for new locks installed in the Premises and Tenant shall have
no further right to possession of the Premises. In the event Landlord shall
elect so to relet, then rent received by Landlord from such reletting shall
be applied first, to the payment of any indebtedness other than Rent due
hereunder from Tenant to Landlord (in such order as Landlord shall
designate), second, to the payment of any cost of such reletting, including,
without limitation, refurbishing costs, reasonable attorneys' fees,
advertising costs, brokerage fees and leasing commissions, and third, to the
payment of Rent due and unpaid hereunder (in such order as Landlord shall
designate), and Tenant shall satisfy and pay any deficiency upon demand
thereof from time to time. No re-entry or taking of possession of the
Premises by Landlord pursuant to this Paragraph 19B shall be construed as an
election on Landlord's part to terminate this Lease unless a written notice
of such termination is given to Tenant pursuant to Paragraph 19A above and,
notwithstanding any such reletting without termination, Landlord may at any
time thereafter elect to terminate this Lease for such previous breach. If
Landlord relets the Premises, either before or after the termination of this
Lease for a rental rate greater than the Rent provided in this Lease, then
for that portion of the Premises that is subject to such new lease, all such
excess rentals shall be and remain the exclusive property of Landlord, and
Tenant shall not be, at any time, entitled to recover said excess rental.
C. Landlord may, without judicial process enter upon the
Premises, by force if necessary, without having any civil or criminal
liability therefor (including specifically any liability or duty under
Section 93.002 of the Texas Property Code which is superseded by this
Paragraph 19C), and do whatever Tenant is obligated to do under the terms of
this Lease, and Tenant agrees to reimburse Landlord on demand for any
expenses which Landlord may incur in effecting compliance with Tenant's
obligations under this Lease plus an administrative fee equal to ten percent
(10%) of the amount of such reimbursement. Tenant further agrees that
Landlord shall not be liable for any damages resulting to Tenant from such
action, whether caused by the negligence of Landlord or otherwise.
D. Any repossession of or re-entering on the Premises by Landlord
under this Article shall be without liability or responsibility for damages
to Tenant. No repossession of or re-entering upon the Premises or any part
thereof pursuant to Paragraphs 19B or 19C or otherwise and no reletting of
the Premises or any part thereof pursuant to Paragraph 19B shall relieve
Tenant or any guarantor of its liabilities and obligations hereunder, all of
which shall survive such repossession or re-entering. In the event of any
such repossession of or re-entering upon the Premises or any part thereof by
reason of the occurrence of an event of default Tenant will continue to pay
to Landlord Rent required to be paid by Tenant.
E. No right or remedy herein conferred upon or reserved to
Landlord is intended to be exclusive of any other right or remedy, and each
and every right and remedy shall be cumulative and in addition to any other
right or remedy given hereunder or now or hereafter existing at law or in
equity or by statute. In addition to the other remedies provided in this
Lease, Landlord shall be entitled, to the extent permitted by applicable law,
to injunctive relief in case of the violation, or attempted or threatened
violation, of any of the covenants, agreements conditions or provisions
COMMERCIAL LEASE AGREEMENT PAGE 16
of this Lease, or to a decree compelling performance of any of the covenants,
agreements, conditions or provisions of this Lease, or to any other remedy
allowed to Landlord at law or in equity. Tenant shall indemnify and hold
Landlord harmless from any and all costs, expenses (including reasonable
attorneys' fees), claims and causes of action arising from or in connection
with any default by Tenant under this Lease.
F. If Landlord repossesses the Premises pursuant to the authority
herein granted or provided at law or in equity, then Landlord shall have the
right to (i) keep in place and use or (ii) remove and store all of the
furniture, fixtures and equipment at the Premises, including that which is
owned by or leased to Tenant at all times prior to any foreclosure thereon by
Landlord or repossession thereof by any lessor thereof or third party having
a superior lien thereon. Landlord also shall have the right to relinquish
possession of all or any portion of such furniture, fixtures, equipment and
other property to any person (CLAIMANT) who presents to Landlord a copy of
any instrument represented by Claimant to have been executed by Tenant (or
any predecessor of Tenant) granting Claimant the right under various
circumstances to take possession of such furniture, fixtures, equipment or
other property, without the necessity on the part of Landlord to inquire into
the authenticity or legality of said instrument. The rights of Landlord
herein stated shall be in addition to any and all other rights that Landlord
has or may hereafter have at law or in equity; and Tenant stipulates and
agrees that the rights herein granted Landlord are commercially reasonable.
G. To the extent required under Texas law, Landlord agrees to use
reasonable efforts to mitigate any of its damages arising from the occurrence
of an event of default by Tenant involving Tenant's abandonment of the
Premises. Tenant agrees that this requirement to use reasonable efforts will
have been satisfied by Landlord: (i) notifying its leasing agent of the
availability of the Premises for rent, and (ii) showing the Premises to
prospective tenants who request to see the Premises and to prospective
tenants referred to Landlord by Tenant. In no event shall Landlord be deemed
not to have mitigated its damages if Landlord chooses to lease some or all of
other space in the Building or the Project or, as applicable, the
Development, to a prospective tenant, rather than some or all of the Premises.
20. DEFAULT BY LANDLORD AND TENANT'S REMEDIES. If Landlord fails to
perform any of its obligations hereunder within thirty (30) days after
written notice from Tenant specifying such failure, or if such obligations
cannot reasonably be accomplished in thirty (30) days, Landlord has not
commenced performance within such thirty (30) day period and thereafter
diligently prosecutes performance through completion, Tenant's exclusive
remedy shall be an action for actual damages. In no event shall Landlord be
liable to Tenant for consequential, punitive or special damages (or any
similar types of damages) by reason of a failure to perform (or a default) by
Landlord hereunder or otherwise. Unless and until Landlord fails to so cure
any default after such notice, Tenant shall not have any remedy or cause of
action by reason thereof. All obligations of Landlord hereunder will be
construed as covenants, not conditions; and all such obligations will be
binding upon Landlord only during the period of its ownership of the Premises
and not thereafter. The term "Landlord" shall mean only the owner, for the
time being, of the Premises, and in the event of the transfer by such owner
of its interest in the Premises, such owner shall thereupon be released and
discharged from all covenants and obligations of the Landlord thereafter
accruing, but such covenants and obligations shall be binding during the term
of this Lease upon each new owner for the duration of such owner's ownership.
Notwithstanding any provisions of this Lease to the contrary, the liability of
Landlord to Tenant for any default by Landlord under the terms of this Lease
shall be limited to Landlord's interest in the Project, and Tenant agrees to
look solely to Landlord's interest in the Project and for recovery of any
judgment from Landlord, it being intended and agreed that Landlord shall not
be personally liable for any judgment or deficiency.
21. BANKRUPTCY.
A. Notwithstanding anything in this Lease to the contrary, all
amounts payable by Tenant to or on behalf of Landlord under this Lease,
whether or not expressly denominated as Rent, shall constitute rent for the
purposes of Section 502(b)(6) of the Bankruptcy Code.
B. This a contract under which applicable law excuses Landlord
from accepting performance from (or rendering performance to) any person or
entity other than Tenant within the meaning of Sections 365(c) and 365 (e)(2)
of the Bankruptcy Code.
22. SECURITY DEPOSIT. Tenant agrees to deposit with Landlord on the
date hereof an amount equal to
COMMERCIAL LEASE AGREEMENT PAGE 17
$24,825.33 which shall be held by Landlord, without obligation for interest,
as security for the performance of Tenant's obligations under this Lease, it
being expressly understood and agreed that this deposit is not an advance
rental deposit or a measure of Landlord's damages in case of Tenant's
default. Upon each occurrence of an event of default by Tenant, Landlord may
use all or part of the deposit to pay past due Rent or other payments due
Landlord under this Lease, and the cost of any other damage, injury, expense
or liability caused by such event of default without prejudice to any other
remedy provided herein or provided by law. On demand, Tenant shall pay
Landlord the amount that will restore the security deposit to its original
amount. The security deposit shall be deemed the property of Landlord, but
any remaining balance of such deposit shall be returned by Landlord to Tenant
when Tenant's obligations under this Lease have been fulfilled and this Lease
terminated, all in accordance with Applicable Laws.
23. WAIVER OF SECURITY INTEREST. Landlord hereby waives and negates any
and all contractual liens and security interests, statutory liens and
security interests or constitutional liens and security interests arising by
operation of law or otherwise to which Landlord might now or hereafter be
entitled on all property of Tenant now owned or hereafter placed in or upon
the Premises (except for judgment liens which may hereafter arise in favor of
Landlord).
24. SURRENDER UPON TERMINATION. At the termination of this Lease, by
its expiration or otherwise, Tenant immediately shall deliver possession of
the Premises to Landlord in good condition and repair and with all repairs
and maintenance required herein to be performed by Tenant completed,
including, without limitation, repairs and maintenance of all heating and air
conditioning systems and equipment therein, reasonable wear and tear and
damage due to fire or other casualty excepted. All obligations of Tenant
hereunder not fully performed as of the expiration or earlier termination of
the term of this Lease shall survive the expiration or earlier termination of
the term hereof.
25. HOLDING OVER. If, for any reason, Tenant retains possession of the
Premises after the expiration or termination of this Lease, unless the
parties hereto otherwise agree in writing, such possession shall be subject
to termination by either Landlord or Tenant at any time upon not less than
ten (10) days advance written notice, and all of the other terms and
provisions of this Lease shall be applicable during such period, except that
Tenant shall pay Landlord from time to time, upon demand, as rental for the
period of such possession, an amount equal to 150% of the Base Monthly Rent
in effect on the termination date, computed on a daily basis for each day of
such period. No holding over by Tenant, whether with or without consent of
Landlord, shall operate to extend this Lease except as otherwise expressly
provided. The preceding provisions of this Paragraph 25 shall not be
construed as consent for Tenant to retain possession of the Premises in the
absence of written consent thereto by Landlord. In addition to the above,
Tenant shall be liable to Landlord for Landlord's actual damages resulting as
a result of any holdover by Tenant.
26. QUIET ENJOYMENT. Landlord covenants that on or before the
Commencement Date it will have good title to the Premises, free and clear of
all liens and encumbrances, excepting only the lien for current taxes not yet
due, such mortgage or mortgages as are permitted by the terms of this Lease,
zoning ordinances and other building and fire ordinances and governmental
regulations relating to the use of such property, and easements, restrictions
and other conditions of record. Landlord agrees that so long as Tenant pays
all amounts due hereunder and performs all other covenants and agreements
herein set forth, Tenant shall peaceably and quietly have, hold and enjoy the
Premises for the term of this Lease without hindrance or molestation from
Landlord, subject to the terms and provisions of this Lease.
27. ENTRY BY LANDLORD. Landlord and Landlord's agents and
representatives shall have the right to enter the Premises at any reasonable
time during business hours, to inspect the Premises and to make such repairs
as may be required or permitted pursuant to this Lease or to make such
repairs or installations as are necessary for other tenants in the Building.
During the period that is six (6) months prior to the end of the term of this
Lease, upon telephonic notice to Tenant, Landlord and Landlord's
representatives may enter the Premises during business hours for the purpose
of showing the Premises. In addition, Landlord shall have the right to erect
a suitable sign on the Premises stating the Premises are available. Landlord
shall also have the right (but not the obligation) to enter the Premises at
any time, and by force if necessary, in the case of an emergency. Tenant
shall notify Landlord in writing at least thirty (30) days prior to vacating
the Premises and shall arrange to meet with Landlord for a joint inspection
of the Premises prior to vacating. If Tenant fails to give such notice or to
arrange for such inspection, then Landlord's inspection of the Premises shall
be deemed correct for the purpose of determining Tenant's responsibility for
repairs and restoration of the Premises.
COMMERCIAL LEASE AGREEMENT PAGE 18
28. MECHANICS LIENS. Tenant has no authority, express or implied, to
create or place any lien or encumbrance of any kind or nature whatsoever
upon, or in any manner to bind the interest of Landlord or Tenant in the
Premises or the Project or to charge the Rent payable hereunder for any claim
in favor of any person dealing with Tenant, including those who may furnish
materials or perform labor for any construction or repairs. Tenant covenants
and agrees that it will pay or cause to be paid all sums legally due and
payable by it on account of any labor performed or materials furnished in
connection with any work performed at the Premises or the Project and that it
will indemnify and hold Landlord harmless from and against any and all loss,
cost or expense based on or arising out of asserted claims or liens against
the leasehold estate or against the right, title and interest of Landlord in
the Premises or the Project or under the terms of this Lease. Tenant agrees
to give Landlord immediate written notice of the placing of any lien or
encumbrance against the Premises or the Project.
29. WAIVER. No waiver by either party hereto of any provision of this
Lease or of any default, event of default or breach by the other shall be
deemed to be a waiver of any other provision of this Lease, or of any
subsequent default, event of default or breach by such party of the same or
any other provision. A party's consent to or approval of any act by the other
that requires such approval or consent shall not be deemed to render
unnecessary the obtaining of such consent to or approval of any subsequent
act of such party. No act or thing done by Landlord or Landlord's agents
during the term of this Lease shall be deemed an acceptance of a surrender of
the Premises, unless done in writing signed by Landlord. The delivery of the
keys to any employee or agent of Landlord shall not operate as a termination
of this Lease or a surrender of the Premises. The acceptance of any Rent by
Landlord following a default, event of default or breach of this Lease by
Tenant shall not constitute a waiver by Landlord of such default, event of
default or breach or any other default, event of default or breach unless
such waiver is expressly stated in writing and signed by Landlord.
30. SUBORDINATION. Conditioned upon the beneficiary of any mortgages
and/or deeds of trust now existing or hereafter placed upon the Premises
entering into an agreement (herein an ATTORNMENT AGREEMENT) with Tenant in
which such beneficiary agrees not to disturb the possession and other rights
of Tenant under this Lease so long as Tenant is not in default in the
performance of its obligations hereunder, and, in the event of the
acquisition of title by such beneficiary through foreclosure proceedings or a
deed in lieu of foreclosure, to accept Tenant as tenant of the Premises under
the terms and conditions of this Lease, Tenant accepts this Lease subject and
subordinate to any mortgages and/or deeds of trust now or hereafter
constituting a lien or charge upon the Premises, provided, however, that if
the mortgagee, trustee, or holder of any such mortgage or deed of trust
elects to have Tenant's interest in this Lease superior to any such
instrument, then by notice to Tenant from such mortgagee, trustee or holder,
this Lease shall be deemed superior to such lien, whether this Lease was
executed before or after said mortgage or deed of trust. Subject to the
foregoing, Tenant, at any time hereafter on demand, shall execute any
instruments, releases or other documents that may be required by any
mortgagee for the purpose of subjecting and subordinating this Lease to the
lien of any such mortgage. For purposes of this section, Landlord will be
deemed to have satisfied the condition of obtaining an Attornment Agreement
if the form thereof required by the mortgagee is a type of form that is
customarily given by institutional lenders, provided that Tenant shall have
the right to attempt to negotiate more favorable terms.
31. TENANT ESTOPPELS. Tenant agrees, from time to time, within ten
(10) days after request of Landlord to deliver to Landlord, or Landlord's
designee, a certificate of occupancy and an estoppel certificate stating that
this Lease is in full force and effect, the date to which Rent has been paid,
the unexpired term of this Lease and such other factual matters pertaining to
this Lease as may be requested by Landlord. It is understood and agreed that
Tenant's obligation to furnish such estoppel certificates in a timely fashion
is a material inducement for Landlord's execution of this Lease.
32. NOTICES. All notices, requests, approvals, and other communications
required or permitted to be delivered under this Lease must be in writing and
are effective (i) on the business day sent if sent by telecopier during
normal business hours and the sending telecopier generates a written
confirmation of sending, (ii) the next business day after delivery to a
nationally-recognized-overnight-courier service for prepaid overnight
delivery; (iii) if orderly delivery of the mail is not then disrupted or
threatened, in which event some method of delivery other than the mail must
be used, three (3) days after being deposited in the United States mail,
certified, return receipt requested, postage prepaid; or (iv) upon actual
receipt by the addressee if delivered personally or by any method other than
by telecopier (with written confirmation),
nationally-recognize-overnight-courier service, or mail, in each instance
addressed to Landlord or Tenant,
COMMERCIAL LEASE AGREEMENT PAGE 19
as the case may be, addressed:
if to Landlord, as follows:
MEPC Quorum Properties II Inc.
00000 Xxxxxx Xxxxxxx, Xxxxx 000, XX 10
Xxxxxx, Xxxxx 00000
Attn: Property Manager
Telecopy: (000) 000-0000
and, if to Tenant, as follows:
Mannatech, Inc.
000 X. Xxxxx Xxxx
Xxxxx 000
Xxxxxxx, Xxxxx 00000
Attn: Xxxxxx X. Xxxxx
Telecopy: (000) 000-0000
or to such other address or to the attention of such other person as shall be
designated by the applicable party and on fifteen (15) days notice from time to
time in writing and sent in accordance herewith.
33. PARKING. Tenant and its employees, customers and licensees shall
have the exclusive right to use any parking areas that have been specifically
designated for such exclusive use by Landlord on the Site Plan, subject to
(i) all rules and regulations promulgated by Landlord in its reasonable
discretion, and (ii) rights of ingress and egress of other lessees of the
Project or the Development, as applicable. Tenant and its employees,
customers and licensees shall not have the right to use any parking area that
are from time to time specifically designated by Landlord for exclusive use
by another lessee, except to the extent necessary for ingress and egress.
Landlord shall not be responsible for enforcing Tenant's parking rights
against any third parties. Tenant agrees not to use more spaces than so
provided.
34. OPTION TO RENEW.
A. If Tenant is not in default under this Lease at the time of the
exercise of this option or at the commencement of the applicable Lease Term
extension, Tenant is granted the option (the OPTION) to extend the Lease Term
for one (1) extension term of five (5) years commencing on the next day after
the expiration of the initial Lease Term by giving Landlord all extension
notice at least nine (9) months, but not more than twelve (12) months, prior
to the expiration of the initial Lease Term. Tenant's lease of the Premises
during the extended Lease Term will be upon the same terms as in the Lease
for the initial Lease Term, except that (i) Base Monthly Rent will adjust on
the first day of the extended Lease Term to the Market Rate (defined below),
and (ii) during the extended Lease Term Tenant will have no further options
or rights to extend the Lease Term.
B. Within thirty (30) days after Landlord receives Tenant's written
notice of its exercise of the Option, Landlord shall deliver a notice to Tenant
(the MARKET RATE NOTICE) specifying the Market Rate for the extended Lease Term,
such to be based upon Landlord's reasonable and good-faith determination of
rents being charged for comparable space in similar properties in the
Freeport Xxxxx Xxxxxxxxxx Xxxx, Xxxxxxx, Xxxxx, for terms commensurate with
the extended Lease Term and for tenants similarly situated. Tenant shall have
fifteen (15) days (the EXAMINATION PERIOD) from its receipt of the Market
Rate Notice to accept or reject Landlord's designation of the Market Rate. If
Tenant accepts Landlord's designation of the Market Rate, the MARKET RATE
will be as set forth in the Market Rate Notice, and Tenant's election to
exercise the Option shall be irrevocable. If Tenant fails to accept in
writing Landlord's designation of the Market Rate set forth in the Market
Rate Notice during the Examination Period, Tenant shall be deemed to have
rejected Landlord's designation of the Market Rate. If Tenant rejects or is
deemed to have rejected Landlord's designation of the Market Rate and
Landlord and Tenant cannot agree in writing on the Market Rate within the
earlier to occur of (i) fifteen (15) days after the date Landlord receives
Tenant's written rejection of Landlord's designation of
COMMERCIAL LEASE AGREEMENT PAGE 20
the Market Rate set forth in the Market Rate Notice, or (ii) fifteen (15)
days after the expiration of the Tenant is deemed to have rejected Landlord's
designation of the Market Rate as set forth in the Market Rate Notice (in
either of such instances, the NEGOTIATION PERIOD), then Tenant will be deemed
to have elected to revoke its exercise of the Option, and this Lease will
expire in accordance with Paragraph 1 above.
C. Tenant may not assign the Option to any assignee (except an
Affiliate) or sublessee of this Lease. No sublessee and no assignee (except an
Affiliate) may exercise the Option.
D. If the Lease Term is extended under this Xxxxxxxxx 00, Xxxxxxxx
shall prepare, and Landlord and Tenant will execute and deliver an amendment
to the Lease extending the Lease Term within fifteen (15) days after the
Market Rate is determined but in no event later than the date that the
applicable extension term commences; provided, however, that the failure of
the parties to enter into such an amendment will not affect the validity of
Tenant's exercise of the Option or the obligations of the parties during the
extended Lease Term.
35. RIGHT OF FIRST REFUSAL ON ADJACENT SPACE.
A. If at any time during the first three (3) years of the Lease
Term Landlord receives a bona fide offer from a third party (the THIRD PARTY
OFFER) for the lease of that space shown on the Site Plan as the Refusal
Space, such consisting of approximately 24,600 square feet, or any portion
thereof, that Landlord wants to accept, and conditioned upon Tenant not then
being in default hereunder, Landlord will first provide Tenant with written
notice (the REFUSAL NOTICE) thereof. Tenant will have seven (7) business days
(the REFUSAL PERIOD) from the date it receives the Refusal Notice to elect to
lease all, but not less than all, of the Refusal Space. If Tenant has not
notified Landlord in writing of such election prior to the expiration of the
Refusal Period, then Tenant shall be deemed to have elected not to lease the
Refusal Space. If Tenant timely and properly elects to lease the Refusal
Space, such lease, shall be on the same terms and conditions for the
Premises, as defined in Paragraph 1 above, provided that Base Monthly Rent
and Adjustments shall be increased proportionately and further provided that
the Work Allowance for the Refusal Space shall be an amount equal to the
product of $3.00 per square foot of the actual Refusal Space multiplied by a
fraction, the numerator of which is the number of months then remaining in
the Lease Term (without giving effect to any option to extend the Lease Term)
and the denominator of which is 122. Tenant's election to lease the Refusal
Space shall be irrevocable once given and from and after the date thereof,
the term PREMISES shall mean and include not only the Premises as defined in
Paragraph 1 above, but also the Refusal Space.
B. In the event Tenant does not elect (or is deemed to have not
elected) to lease the Refusal Space, Landlord shall have a period of two
hundred seventy (270) days from the date the Refusal Period expires (the
MARKETING PERIOD) to market the Refusal Space, or any portion thereof, for
lease on terms wholly within Landlord's discretion and during which period
Landlord will not have any obligations to Tenant under this Paragraph 35. If
Landlord has not entered into a binding lease with a third party during the
Marketing Period, the right of first refusal set forth in this Paragraph 35
shall again become effective and Landlord may not lease the Refusal Space, or
any portion thereof, without compliance with this Paragraph 35; provided,
however, that all rights of Tenant in and under this Paragraph 35 shall in
any event expire on that date which is the third anniversary of the date of
this Lease if not exercised by Tenant prior to such time.
C. Tenant may not assign its rights under this Paragraph 35 to
any assignee or sublessee of this Lease, nor may any sublessee or assignee
have any rights under this Paragraph 35.
D. If Tenant leases the Refusal Space, Landlord shall prepare,
and Landlord and Tenant will execute and deliver an amendment to the Lease
confirming the lease of the Refusal Space and the new Base Monthly Rent and
Adjustments; provided, however, that the failure of the parties to enter into
such an amendment will not affect the validity of Tenant's lease of the
Refusal Space or the obligations of the parties with respect thereto.
36. MISCELLANEOUS.
A. REQUIRED CONSENT. To the extent the approval or consent is
required of any party hereto, such party agrees that such consent or approval
may not be unreasonably withheld, delayed or conditioned unless the provision
COMMERCIAL LEASE AGREEMENT PAGE 21
where the requirement for such consent or approval is imposed includes an
express statement that such approval or consent may be withheld in such
party's sole discretion.
B. FINANCIAL STATEMENTS. During each Lease Year, and upon written
request by Landlord, Tenant shall provide to Landlord true, correct and complete
copies of Tenant's year end financial statements and quarterly, non-audited,
balance sheets certified by the chief financial officer (or its equivalent) of
Tenant.
C. CONFIDENTIALITY. Tenant shall keep the terms and provisions of
this Lease confidential at all times and not disclose the terms and provisions
hereof to any party without Landlord's prior written consent, which may be
withheld by Landlord in its sole discretion. Landlord hereby consents to the
disclosure of the terms and provisions of this Lease to employees of Tenant,
Tenant's attorneys and to any financial institution Tenant is seeking financing
from in connection with this Lease and/or Tenant's operations at the Premises.
The terms of this paragraph and Tenant's agreement thereto are a material
inducement to Landlord entering into this Lease, and Tenant agrees that Landlord
may be severely damaged by a breach of this paragraph and the confidentiality
obligations herein contained. Tenant agrees that in the event of a breach of
this paragraph, Landlord may, in addition to any other remedies it may have
under this Lease or at law or equity, seek injunctive relief against Tenant
and/or recover damages from Tenant.
D. HEADINGS/GENDER. Words of any gender used in this Lease shall
be held and construed to include any other gender, and words in the singular
number shall be held to include the plural, unless the context otherwise
requires. The captions inserted in this Lease are for convenience only and in
no way define, limit or otherwise describe the scope or intent of this Lease,
or any provision hereof, or in any way affect the interpretation of this
Lease.
E. RUN WITH THE LAND. The terms, provisions and covenants and
conditions contained in this Lease shall run with the land and shall apply to,
inure to the benefit of, and be binding upon, the parties hereto and upon their
respective heirs, executors, personal representatives, legal representatives,
successor and assigns, except as otherwise herein expressly provided. Landlord
shall have the right to transfer and assign, in whole or in part, its rights and
obligations in the Premises, Building and/or Project that are the subject of
this Lease. Each party agrees to furnish to the other, promptly upon demand,
a corporate resolution, proof of due authorization by partners, or other
appropriate documentation evidencing the due authorization of such party to
enter into this Lease.
F. ORGANIZATION AND AUTHORITY.
(i) Tenant represents and warrants to Landlord that (i) Tenant is
a duly organized and existing Texas corporation and has the full right and
authority to enter into this Lease and to perform all of its obligations
hereunder, (ii) all requisite authorizing actions have been taken by Tenant
in connection with the entering into of this Lease, and (iii) each of the
persons signing this Lease on behalf of Tenant is authorized to do so. Upon
request by Landlord, Tenant will provide a certified copy of the
resolutions of the board of directors of Tenant authorizing the entering
into of this Lease by Tenant and the execution hereof by the persons who
sign this Lease on behalf of Tenant;
(ii) Landlord represents and warrants to Tenant that (i) Landlord
is a duly organized and existing Delaware corporation and has the full
right and authority to enter into this Lease and to perform all of its
obligations hereunder, (ii) all requisite authorizing actions have been
taken by Landlord in connection with the entering into of this Lease, and
(iii) each of the persons signing this Lease on behalf of Landlord is
authorized to do so. Upon request by Tenant, Landlord will provide a
certified copy of the resolutions of the board of directors of Landlord
authorizing the entering into of this Lease by Landlord and the execution
hereof by the persons who sign this Lease on behalf of Landlord.
G. RECORDING. Tenant may not record this Lease or any memorandum
thereof.
H. ENTIRE AGREEMENT. This Lease constitutes the entire
understanding and agreement of the Landlord and Tenant with respect to the
subject matter of this Lease, and contains all of the covenants and
agreements of Landlord and Tenant with respect thereto. Landlord and Tenant
each acknowledge that no representations, inducements, promises or
agreements, oral or written, have been made by Landlord or Tenant, or anyone
acting on behalf of Landlord or Tenant, which are not contained herein, and
any prior agreements, promises, negotiations, or representations not
expressly
COMMERCIAL LEASE AGREEMENT PAGE 22
set forth in this Lease are of no force or effect. This Lease may not be
altered, changed or amended except by all instrument in writing signed by
both parties hereto.
I. FORCE MAJEURE. As used in this Lease, FORCE MAJEURE shall mean
a delay caused by reason of fire, acts of God, unreasonable delays in
transportation, embargo, weather (I.E., rain and rain related conditions,
humidity, temperature, wind, etc.), strike, other labor disputes,
governmental preemption of priorities or other controls in connection with a
national or other public emergency, governmental delays in permitting, delays
caused by any governmental disapproval of, or required revisions to, the
Finish Plans, or shortages of fuel, supplies or labor or any similar cause
not within Landlord's reasonable control. Landlord shall not be held
responsible for delays in the performance of its obligations hereunder caused
by Force Majeure, and such delays shall be excluded from the computation of
the time allowed for the performance of such obligations. It is expressly
agreed that the number of delay days may include not only the day or days
upon which the event of Force Majeure occurred but the number of days
thereafter that work could not resume due to the occurrence of such event of
Force Majeure. By way of example only, rain on a Sunday, which is not
scheduled as a normal work day, may prevent work for several days thereafter
due to mud conditions.
J. SEVERABILITY. If any clause or provision of this Lease is
illegal, invalid, or unenforceable under present or future laws effective
during the term of this Lease, then and in that event, it is the intention of
the parties hereto that the remainder of this Lease shall not be affected
thereby, and it is also the intention of the parties to this Lease that in
lieu of each clause or provision of this Lease that is illegal, invalid or
unenforceable, there be added, as a part of this Lease, a clause or provision
as similar in terms to such illegal, invalid or unenforceable clause or
provision as may be possible and be legal, valid and enforceable.
K. DATE OF LEASE. All references in this Lease to "the date
hereof" or similar references shall be deemed to refer to the last date, in
point of time, on which all parties hereto have executed this Lease.
L. BROKERS.
(1) Tenant represents and warrants that, except for The
Amend Group (BROKER), Tenant has not dealt with any broker, agent or other
person in connection with this transaction and that, except for Broker, no
broker, agent or other person brought about this transaction through the
acts of or employment by Tenant, and, except with respect to any commission
or fee owed to Broker, Tenant agrees to indemnify and hold Landlord
harmless from and against any claims by any broker, agent or other person
claiming a commission or other form of compensation by virtue of having
dealt with Tenant with regard to this leasing transaction.
(2) Landlord represents and warrants that, except for
Broker, Landlord has not dealt with any broker, agent or other person in
connection with this transaction and that, except for Broker, no broker,
agent or other person brought about this transaction through the acts of
or employment by Landlord. Landlord has agreed to pay Broker a commission
pursuant to a separate written agreement between Landlord and Broker, and
Landlord agrees to indemnify and hold Tenant harmless from and against any
claims by Broker or any broker, agent or other person claiming a commission
or other form of compensation by virtue of having dealt with Landlord with
regard to this leasing transaction.
M. COUNTERPARTS. This Lease may be executed in counterparts, each
being deemed an original, but together constituting only one instrument.
N. TIME FOR PERFORMANCE. TIME IS OF THE ESSENCE WITH RESPECT TO ALL
PERFORMANCE OBLIGATIONS CONTAINED IN THIS LEASE.
O. ATTORNEYS FEES. In the event it becomes necessary for either
party hereto to file a suit to enforce this Lease or any provisions contained
herein, the party prevailing in such action shall be entitled to recover, in
addition to all other remedies or damages, reasonable attorneys fees incurred
in such suit.
P. LAW GOVERNING. This Lease shall be construed and interpreted in
accordance with the laws of the
COMMERCIAL LEASE AGREEMENT PAGE 23
State of Texas and the obligations of the parties hereto are and shall be
performable in, and venue for any claim or cause of action shall reside in,
Dallas County, Texas.
Q. AMENDMENTS. This Lease may not be modified or amended, except
by an agreement in writing signed by Landlord and Tenant. The parties may
waive any of the conditions contained herein or any of the obligations of the
other party hereunder, but any such waiver shall be effective only if in
writing and signed by the party waiving such conditions or obligations,
except as specifically set forth herein.
EXECUTED BY Landlord, this 29TH day of MAY, 1997.
MEPC QUORUM PROPERTIES II INC., a
Delaware corporation
By: /s/ XXXXX XXXXXXX
----------------------------------
Name: XXXXX XXXXXXX
--------------------------------
Title: Executive Vice President
-------------------------------
By: /s/ XXXXX X. XXXXXXX
----------------------------------
Name: XXXXX X. XXXXXXX
--------------------------------
Title: Vice President
-------------------------------
EXECUTED BY Tenant, this 29TH day of MAY, 1997.
MANNATECH, INC., a Texas corporation
By: /s/ XXXXXXX X. XXXXXXXX
----------------------------------
Name: XXXXXXX X. XXXXXXXX
--------------------------------
Title: Chairman of the Board
-------------------------------
EXHIBITS:
Exhibit A: Legal Description of 28 Acre Tract
Exhibit B: Shell Building Construction Features
Exhibit C: Site Plan
Exhibit D: Omitted
Exhibit E: Acceptance of Premises Memorandum
Exhibit F: Contractor Insurance Requirements
COMMERCIAL LEASE AGREEMENT PAGE 24
EXHIBIT "A"
LEGAL DESCRIPTION OF 28 ACRE TRACT
Being a tract or parcel of land situated in the Xxxxxxx X. Xxxxx Survey,
Abstract No. 1140 and the X. X. Xxxxxxxx Survey, Abstract No. 1655, City of
Coppell, Dallas County, Dallas, Texas, same being a portion of "Freeport
North", a Preliminary-Final Plat recorded in Volume 84203, Page 1835, Dallas
County Plat Records, same also being all of that certain 27.8527 acre Tract 5
conveyed to T/E Freeport North Land, Ltd. by instrument of record in Volume
94222, Page 1168, Dallas County Deed Records, said tract being more
particularly described by metes and bounds as follows:
BEGINING at a 1/2 inch iron rod set in the Easterly line of that certain
157.929 acre tract of land conveyed to San Antonio Savings Association, F.A.
by instrument of record in Volume 92104, Page 4313, Dallas County Deed
Records, same being in the Northwesterly corner of said 27.8527 acre tract,
same being in the Southerly line of Xxxxxxxxxx Xxxxx, 00 feet wide, from
which a 1/2 inch iron rod found bears North 00 degrees 13 minutes 53 seconds
West, 80.21 feet;
THENCE, along said Southerly line, South 89 degrees 45 minutes 41 seconds
East, 1268.29 feet to a 1/2 inch iron rod set for corner;
THENCE, continuing along said Southerly line, South 28 degrees 41 minutes 54
seconds East, 14.50 feet to a 1/2 inch iron rod set for corner in the
Westerly line of Royal Lane, 100 feet wide;
THENCE, along said Westerly line the following five (5) courses:
1) 81.48 feet along the arc of a non-tangent curve to the right having
a radius of 950.00 feet, a central angle of 04 degrees 54 minutes 51
seconds and a chord bearing and distance of South 35 degrees 16 minutes
31 seconds West, 81.45 feet to a 1/2 inch iron rod set for a point of
tangency;
2) South 37 degrees 43 minutes 57 seconds West, 170.92 feet to a 1/2
inch iron rod set for the beginning of a curve;
3) 684.33 feet along the arc of a tangent curve to the left having a
radius of 1050.00, a central angle of 37 degrees 20 minutes 31 seconds
and a chord bearing and distance of South 19 degrees 03 minutes 41
seconds West, 672.28 feet to a 1/2 inch iron rod set for a point of
tangency;
4) South 00 degrees 23 minutes 26 seconds West, 279.79 feet to a 1/2
inch iron rod set for corner;
5) South 45 degrees 23 minutes 26 seconds West, 21.21 feet to a 1/2
inch iron rod set for corner in the Northerly line of Xxxxxxxx
Xxxxxxxxx, 00 feet wide;
THENCE, departing said Westerly line and along said Northerly line the
following four (4) courses:
1) North 89 degrees 36 minutes 34 seconds West, 150.17 feet to a 1/2
inch iron rod set for the beginning of a curve;
2) 299.43 feet along the arc of a tangent curve to the left having a
radius of 530.00 feet, a central angle of 32 degrees 22 minutes 11
seconds and a chord bearing and distance of South 74 degrees 12
minutes 20 seconds West, 295.46 feet to a 1/2 inch iron rod set for
a point of reverse curvature;
3) 262.43 feet along the arc of a tangent curve to the right having a
radius of 470.00 feet, a central angle of 32 degrees 00 minutes 00
seconds and a chord bearing and distance of South 74 degrees 01 minutes
15 seconds West, 259.10 feet to a 1/2 inch iron rod set for a point
of tangency;
4) North 89 degrees 58 minutes 45 seconds West, 199.72 feet to a 1/2
inch iron rod set for corner in the common line of said 157.929 acre
tract and said 27.8527 acre tract;
THENCE along said common line, North 00 degrees 02 minutes 58 seconds East,
305.12 feet to a 5/8 inch iron rod found for corner:
THENCE continuing along said common line, North 00 degrees 13 minutes 53
seconds West, 995.31 feet to the POINT OF BEGINNING and CONTAINING 27.8527
acres, 1,213,263 square feet, more or less, of land area within these metes
and bounds.
MANNATECH
EXHIBIT B
SHELL BUILDING CONSTRUCTION FEATURES
SHELL BUILDING CONSTRUCTION FEATURES
- Painted exterior concrete tilt wall construction
- 30' Clear Height to the bottom of the roof joist
- 40' x 41' column bay dimensions
- Four-ply built-up roof system
- 6" thick reinforced concrete floor slab
- 6" thick reinforced concrete truck paving
- 5" thick reinforced concrete car parking
- ESFR fire sprinkler system
- (9) 9' x 10' Vertical lift overhead doors
- (5) 30,000 CFM Rooftop exhaust fans
- 4' x 4' skylights
- The building Fire Pump Room (approx. 12' x 18') is located
within this lease space
CLARIFICATIONS AND EXCLUSIONS
- Fire alarm, security, and/or phone systems excluded
- In-rack fire sprinklers or modifications to overhead system excluded
- Dumpster/compactor power and/or screening excluded
- Draft curtains or modifications/additions to smoke removal
system are excluded
[FLOORPLAN]
EXHIBIT "D"
OMITTED
EXHIBIT "E"
ACCEPTANCE OF PREMISES MEMORANDUM
This memorandum is being executed pursuant to the Commercial Lease
Agreement (the LEASE) executed on the ___ day of ______, 1997, between MEPC
QUORUM PROPERTIES II INC., a Delaware corporation (LANDLORD), and MANNATECH,
INC., a TEXAS (TENANT).
Landlord and Tenant hereby agree that:
1. Tenant acknowledges that (i) it has inspected and accepts the Building and
the Project, (ii) the Premises is suitable for the purpose for which it is
leased, subject to completion by Tenant of any finish work Tenant requires,
(iii) the Building and the Project are in good and satisfactory condition,
and (iv) no representations as to the repair of the Premises or the
Project, nor promises to alter, remodel or improve the Premises or the
Project which have been made by Landlord remain unsatisfied.
2. The Commencement Date of the Lease is the ____ day of _________, 199__.
3. The Rent Commencement Date of the Lease is the ____ day of _______, 199__.
4. The expiration date of the Lease is the ____ day of _________, 1997___.
5. All capitalized terms not defined herein shall have the meaning assigned to
them in the Lease.
Agreed and Executed this ___ day of _______, 1997.
LANDLORD TENANT
MEPC QUORUM PROPERTIES II INC., MANNATECH, INC., a TEXAS corporation
a Delaware corporation
By: By:
------------------------------ ------------------------------
Name: Name:
------------------------- -------------------------
Title: Title:
------------------------ ------------------------
By:
------------------------------
Name:
-------------------------
Title:
------------------------
EXHIBIT "F"
CONTRACTOR INSURANCE REQUIREMENTS
All contractors, subcontractors, suppliers, service providers, moving companies,
and others performing work of any type for Tenant at the Premises shall:
- carry the insurance listed below with companies acceptable to
Landlord; and
- furnish Certificates of Insurance to Landlord evidencing required
coverages at least ten (10) days prior to entry in the Premises and
Renewal Certificates at least thirty (30) days prior to the expiration
dates of Certificates previously furnished.
Certificates of Insurance must provide for thirty (30) days' prior written
notice of cancellation or material change to Landlord.
(1) WORKERS COMPENSATION: Statutory workers compensation insurance covering
full liability under applicable Workers Compensation Laws at the required
statutory limits.
(2) EMPLOYERS' LIABILITY: Employers' liability insurance with the following
minimum limits of liability:
$100,000 Each Accident
$500,000 Disease-Policy Limit
$100,000 Disease-Each Employee
(3) COMMERCIAL GENERAL LIABILITY: This insurance policy must:
(a) Be written on a standard liability policy form (sometimes known as
commercial general liability insurance) BUT WITHOUT exclusionary
endorsements that may delete coverage for products/completed
operations, personal and advertising injury, blanket contractual,
fire legal liability, or medical payments.
(b) Be endorsed to provide that:
- aggregate limits, if any, apply separately to each of the
insured's jobs or projects away from premises owned by or rented
to the insured;
- the insurance is primary and non-contributory to any insurance
provided by Landlord; and
- include the following minimum limits:
$1,000,000 General Aggregate
$1,000,000 Products-Completed Operations Aggregate
$1,000,000 Personal & Advertising Injury
$1,000,000 Each Occurrence
$ 50,000 Fire Damage (Any one fire)
$ 5,000 Medical Expense (Any one person)
(4) AUTOMOBILE LIABILITY: Automobile liability insurance for claims of
ownership, maintenance, or use of owned, non-owned, and hired motor
vehicles at, upon, or away from the Premises with the following minimum
limits:
$500,000 Combined Single Limit Bodily Injury and Property
Damage per Occurrence
(5) EXCESS LIABILITY: Following form excess liability insurance with coverages
at least as broad as the required commercial general liability insurance
with the following minimum limits:
$1,000,000 Each Occurrence
$2,000,000 Aggregate
(6) GENERAL REQUIREMENTS: All policies must be:
- written on an occurrence basis and not on a claims-made basis;
- endorsed to name as additional insureds Landlord, and its respective
officers, directors, employees, agents, partners, and assigns;
- endorsed to waive any rights of subrogation against Landlord and its
respective officers, directors, employees, agents, partners, and
assigns; and
- primary and non-contributing with, and not in excess of, any other
insurance available to Tenant and Landlord (or any other entity
named as an additional insured).
FIRST AMENDMENT TO COMMERCIAL LEASE AGREEMENT
THIS FIRST AMENDMENT TO COMMERCIAL LEASE AGREEMENT (this "AMENDMENT") is
entered into by and between MEPC QUORUM PROPERTIES II INC., a Delaware
corporation (LANDLORD) and MANNATECH, INC., a Texas corporation (TENANT)
effective as of November 6, 1997.
A. Landlord and Tenant have heretofore entered into a Commercial Lease
Agreement (the LEASE) pursuant to which Landlord leased to Tenant
approximately 74,476 square feet in the Building (as defined in the Lease)
located on the Land described on EXHIBIT "A" attached to the Lease and
located in the Freeport Xxxxx Xxxxxxxxxx Xxxx, Xxxxxxx, Xxxxx;
B. Landlord and Tenant now wish to amend the Lease.
NOW THEREFORE, for good and valuable consideration, the receipt and
sufficiency of which being hereby acknowledged, Landlord and Tenant hereby
agree as follows:
1. COMMENCEMENT DATE. Landlord and Tenant agree that the COMMENCEMENT
DATE, as that term is used in the Lease, as amended hereby, shall be October
27, 1997.
2. IMPROVEMENTS/TENANT FINISH. Paragraph 2 of the Lease shall be, and
hereby is, deleted and replaced with the following Paragraph 2:
"2. IMPROVEMENTS TO BE CONSTRUCTED BY LANDLORD
A. BUILDING. Landlord agrees to construct on the Land an
approximate 297,902 square foot warehouse building structure (the BUILDING)
containing the features generally described on EXHIBIT "B" attached hereto
and incorporated herein by reference and generally situated as shown on the
Site Plan (herein so called) attached hereto as EXHIBIT "C" and
incorporated herein by reference.
B. TENANT FINISH. Landlord agrees to construct within the
Premises the improvements described in the plans and specifications
prepared by Xxxxxxxxx & Xxxxxxxx (ARCHITECT) and set forth on EXHIBIT "G"
attached hereto and incorporated herein by reference (collectively, the
FINISH PLANS). The improvements to be constructed pursuant to the Finish
Plans are collectively referred to herein as the TENANT FINISH WORK). The
Building, the Tenant Finish Work and any other improvements constructed by
Landlord on the Land from time to time, whether pursuant to this Lease or
otherwise, are collectively referred to herein as the IMPROVEMENTS.
C. CONSTRUCTION COSTS. Subject to the terms of this paragraph,
Landlord will pay (i) the cost of all Tenant Finish Work up to, but not in
excess of the $220,928.00 (the WORK ALLOWANCE), which includes any costs
incurred by Landlord in connection with the preparation of the Finish
Plans, and (ii) the cost of constructing the Building and any other
improvements described on EXHIBIT "B". Notwithstanding the preceding
sentence, Tenant shall be responsible for the following:
(1) If prior to commencement of the Tenant Finish Work
Landlord determines that the actual cost of the Tenant Finish Work
will exceed the Work Allowance, or if during construction the actual
cost of the Tenant Finish Work exceeds the Work Allowance, Landlord
will not be obligated to commence the Tenant Finish Work or continue
its construction until it receives from Tenant ten percent (10%) of
the estimated cost by which such amount is in excess, in Landlord's
estimation, of the Work Allowance, with the actual amount of such
excess, less the initial payment by Tenant, being due on the Rent
Commencement Date.
(2) If Tenant requests any redrawing of the Finish
Plans, Tenant will be responsible for the costs of any redrawing of
such plans in connection with such change(s) and shall reimburse
Landlord for such costs upon demand.
(3) If Landlord performs, at Tenant's request, any
work over and above the work generally described in the Finish Plans
or described on EXHIBIT "B" (herein, the ADDITIONAL WORK), including
any additional work which has been approved by written change order
or work order, then, subject to the exhaustion of the Work Allowance,
the Additional Work together with the cost of preparing plans and
specifications for same will be at Tenant's expense. Landlord will not
be obligated to perform any such Additional Work until Tenant pays
Landlord ten percent (10%) of the estimated cost
of the Additional Work, as estimated by Landlord, with the actual cost
of the Additional Work, less the initial payment by Tenant, being due
on the Rent Commencement Date.
(4) All costs or expenses incurred or suffered by
Landlord that are caused by Tenant Delays. A TENANT DELAY(S) shall
mean any delay in the completion of the Improvements or any delay in
the occurrence of the Commencement Date caused by a Tenant Party,
including, without limitation, any delay resulting from the
installation by Tenant or any Tenant Party of any property or
equipment of Tenant in or on the Premises prior to the Rent
Commencement Date, any delay resulting from any request by Tenant for
any change or modification to the Finish Plans, any delay caused by
any Additional Work requested by Tenant, and any delay due to
interference by Tenant or any Tenant Party with Landlord's engineers,
consultants, contractors or otherwise. As used in this Lease, a TENANT
PARTY shall mean one or more of Tenant, its agents, employees,
officers, partners or contractors.
Additionally, Landlord shall receive an administration fee in the total
amount of 2.50% of the total construction costs of the Tenant Finish Work,
as determined by the general contract for the Tenant Finish Work, as same
may be modified by work or change orders. Such fee shall be charged
against the Work Allowance upon the entering into of such general contract
and at the time the cost of any Additional Work is determined. If there is
no remaining balance of the Work Allowance at any time the administration
fee is owed, such shall be paid by Tenant upon demand. Lastly, all
oversight costs charged by Architect in connection with the Tenant Finish
Work shall be charged against the Work Allowance until exhausted and
thereafter paid by Tenant upon demand.
D. MANNER OF CONSTRUCTION. Landlord agrees to construct the
Improvements in a good and workmanlike manner.
E. OWNERSHIP OF IMPROVEMENTS. All Tenant Finish Work and the
other Improvements constructed by or on behalf of Landlord shall at all
times be the sole property of Landlord."
3. RENT COMMENCEMENT/ACCEPTANCE OF PREMISES. Paragraph 3 of the Lease
shall be, and hereby is, deleted and replaced with the following:
"3. RENT COMMENCEMENT DATE/ACCEPTANCE OF PREMISES.
A. RENT COMMENCEMENT DATE. The RENT COMMENCEMENT DATE shall be
the earlier to occur of (i) ninety (90) days after the Commencement Date,
or (ii) the date Tenant takes possession or commences use of the Premises
for any purpose other than merely to perform any work that may be permitted
under Paragraph 6 below.
B. ACCEPTANCE OF PREMISES. Not less than five (5) days prior to
the date Landlord estimates the Tenant Finish Work will be substantially
complete Landlord will notify Tenant of the estimated date that the Tenant
Finish Work will be substantially completed. The term SUBSTANTIALLY
COMPLETED or SUBSTANTIALLY COMPLETE as used herein, means that, in the
reasonable opinion of Landlord's architect, the Tenant Finish Work has been
completed in substantial accordance with the Finish Plans and that the
Premises is in good and satisfactory condition, subject only to completion
of minor punch list items. Upon receipt of Landlord's notification, Tenant
shall verbally notify Landlord of the date Tenant intends to make its
walk-through inspection of the Premises, such date to be on the date
specified in Landlord's notice for the Tenant Finish Work to be
substantially complete or within three (3) days prior to that date.
Landlord and Landlord's architect shall accompany Tenant on the
walk-through inspection so as to mutually determine the punch list of
items to be completed or repaired by Landlord within a reasonable time
after the date of the walk-through inspection (the PUNCH LIST). At the
conclusion of the walk-through inspection, Tenant will be deemed to have
acknowledged that, subject only to Landlord's completion of the Punch List,
(i) it has inspected and accepts the Premises and the Project, (ii) the
Premises is suitable for the purpose for which it is leased, (iii) the
Premises and the Project are in good and satisfactory condition, and
(iv) no representations as to the repair of the Premises or the Project,
nor promises to alter, remodel or improve the Premises or the Project which
have been made by Landlord remain unsatisfied. At the conclusion of the
walk-through inspection Tenant further agrees to execute an Acceptance of
Premises Memorandum in the form attached hereto and made a part hereof as
EXHIBIT "E", whereupon possession of the Premises will be delivered to
Tenant and Tenant will be deemed to have accepted the Premises, and Tenant
FIRST AMENDMENT -- PAGE 2
may thereafter occupy the Premises. Tenant's failure to conduct a
walk-through inspection or execute the Acceptance of Premises Memorandum
will not delay the occurrence of the Rent Commencement Date."
4. PAYMENT OF RENT. Xxxxxxxxx 0X of the Lease shall be, and hereby is,
deleted and replaced with the following:
"C. PAYMENT OF RENT. Base Monthly Rent and Adjustments shall be due
and payable, in advance, beginning on the Rent Commencement Date; provided
that one (1) full installment of Base Monthly Rent and Adjustments totaling
$24,825.33 is due and payable on the date of this Lease, such to be applied
to the first installment of Base Monthly Rent and Adjustments due on the
Rent Commencement Date and thereafter applied to Base Monthly Rent and
Adjustments until fully applied. Any installment of Base Monthly Rent or
Adjustments due for any fractional calendar month shall be prorated based
upon the actual number of days in that month. If the Rent Commencement Date
occurs on the first day of a calendar month, then the month in which the
Rent Commencement Date occurs shall be the first complete calendar month
after the occurrence of the Rent Commencement Date for purposes of
determining the date upon which Base Monthly Rent adjusts. As used in this
Lease, RENT shall mean the Base Monthly Rent and all other amounts provided
for in this Lease to be paid by Tenant to Landlord, all of which shall
constitute rental in consideration for this Lease and the leasing of the
Premises. All Rent (hereinafter defined) shall be paid at the times and in
the amounts provided for herein in legal tender of the United States of
America to Landlord at the address specified in Paragraph 32 hereof or to
such other person or at such other address as Landlord may from time to
time designate in writing. Rent shall be paid without notice, demand,
abatement, deduction or offset (unless expressly provided for elsewhere in
this Lease) and shall be a covenant of Tenant independent of any obligation
of Landlord under this Lease. Tenant's obligation to pay any installment
of Rent shall not be deemed satisfied until such installment of Rent has
actually been received by Landlord."
5. IMPROVEMENTS/ALTERATIONS BY TENANT. Paragraphs 6A, 6B, and 6C of
the Lease shall be, and hereby are, deleted and replaced with the following:
"A. AFTER COMMENCEMENT DATE. Except as expressly permitted by
this Xxxxxxxxx 0, Xxxxxx may not make or permit any alterations,
improvements, or additions in or to the Premises without Landlord's prior
written consent. All alterations and improvements desired by Tenant are
subject to the following conditions:
(1) All alterations, improvements and additions will
be at the sole cost and expense of Tenant;
(2) All alterations, improvements and additions in and
to the Premises requested by Tenant must be made in accordance with
plans and specifications first approved in writing by Landlord;
(3) Tenant's contractors and subcontractors are
subject to Landlord's prior approval. In addition, each of Tenant's
contractor(s) and subcontractor(s) must deliver evidence satisfactory
to Landlord that the insurance specified on EXHIBIT "F" (attached
hereto and incorporated herein by reference) is in force prior to
commencing work;
(4) All alterations, improvements and additions made
by Tenant must comply with all Applicable Laws including,
specifically, the ADA, and applicable building permits and
certificates of occupancy. Landlord's approval of Tenant's plans and
specifications for the alterations or improvements will not act as a
confirmation or agreement by Landlord that the improvements and
alterations comply with Applicable Laws;
(5) Tenant must deliver to Landlord evidence that
Tenant has obtained all necessary governmental permits and approvals
for the improvements, alterations and additions prior to starting any
work;
(6) All alterations, improvements and additions must
be done in a good and workmanlike manner so as not to damage or alter
the primary structure or structural qualities or the utility or other
systems of the Premises or the Building and is subject to approval by
Landlord during and after construction, in its sole discretion;
FIRST AMENDMENT -- PAGE 3
(7) Lien releases from each of Tenant's contractor(s)
and subcontractor(s) must be submitted to Landlord within ten (10)
days after completion of the work performed by the contractor(s) or
subcontractor(s); and
(8) Tenant shall be solely responsible for the safety
and security of all equipment and property installed or placed in, on
or about the Premises by a Tenant Party.
B. PRIOR TO THE RENT COMMENCEMENT DATE. Prior to the Rent
Commencement Date, and upon written request by Tenant, Tenant and its
contractors may enter the Premises so that Tenant may perform other work
and decorations Tenant wants in the Premises. This license to enter prior
to the Rent Commencement Date is subject to the conditions set forth in
Paragraph 6A above and, in addition, the following conditions:
(9) Tenant's contractor(s) must work in harmony and
not interfere with Landlord's contractors and subcontractors; and
(10) Landlord may revoke this license if the entry
causes interference with the construction of the Improvements and
Tenant does not immediately cease such interference (or cause its
contractors to immediately cease such interference, as the case may
be) after receipt of notice from Landlord, which notice may be
verbal. Any such interference may be deemed a Tenant Delay.
C. TENANT'S PROPERTY. Tenant, at its own cost and expense, may
erect such shelves, racks, bins and trade fixtures (collectively, TENANT'S
PROPERTY) within the Premises as it desires and without Landlord's prior
consent provided that (a) such items do not alter the basic character of
the Premises or the Building; (b) such items do not overload or damage the
Premises or the Building or the utility or other systems serving same; (c)
such items may be removed without material injury to the Premises and the
Building; and (d) the construction, erection or installation thereof
complies with all Applicable Laws, applicable building permits and
certificates of occupancy; and (e) provided that Tenant's installation of
Tenant's Property prior to the Rent Commencement Date will be subject to
Paragraph 6B above. All of Tenant's Property shall remain the property of
Tenant and shall be removed on or before the earlier to occur of the date
of termination of this Lease or Tenant's vacating of the Premises. Tenant
shall promptly repair any damage to the Project or the Premises caused by
the removal of any of Tenant's Property. Any of Tenant's Property not so
removed and any other property of Tenant not removed prior to the
termination of this Lease or Tenant's vacating of the Premises shall
thereupon be conclusively presumed to have been abandoned by Tenant, and
Landlord may, at its option, take over possession of any and all of the
foregoing and either (i) declare the same to be the property of Landlord
by written notice to Tenant at the address provided herein or (ii) at the
sole cost and expense of Tenant, remove, store, and/or dispose of the same
or any part thereof all at Tenant's cost, in any manner that Landlord shall
choose without incurring liability to Tenant or any other person."
6. EXHIBITS. EXHIBIT "E" to the Lease shall be, and hereby is, deleted
and replaced with EXHIBIT "E" as attached to this Amendment. The Lease shall
be, and hereby is, further amended to add as EXHIBIT "G" thereto the Finish
Plans attached to this Amendment as EXHIBIT "G". EXHIBITS "A"-"D" and "F" are
omitted from this Amendment.
7. COUNTERPARTS. This Amendment may be executed in counterparts.
Facsimile signatures will have the same effect as originals.
8. RATIFICATION. The Lease, as amended hereby, is ratified and
confirmed by the parties as being in full force and effect. To the extent of
any conflict between the terms of the Lease and this Amendment, this
Amendment shall govern. All capitalized terms herein shall have the same
meaning as set forth in the Lease unless otherwise noted herein. This
Amendment is binding on the parties and their successors and assigns.
IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment
effective as of the latter of the two dates set forth below.
LANDLORD: MEPC QUORUM PROPERTIES INC., a Delaware
corporation
By: /s/ Xx Xxxxxx
---------------------------------
FIRST AMENDMENT -- PAGE 4
Name: Xx XXXXXX
-------------------------------
Title: SENIOR VICE PRESIDENT
------------------------------
By: /s/ Xxxxx Xxxxxxx
---------------------------------
Name: XXXXX XXXXXXX
-------------------------------
Title: SENIOR VICE PRESIDENT
------------------------------
TENANT: MANNATECH, INC. a Texas corporation
By: /s/ (Illegible)
---------------------------------
Name:
-------------------------------
Title: C.O.O.
------------------------------
FIRST AMENDMENT -- PAGE 5
EXHIBITS "A" - "D"
OMITTED
EXHIBIT "E"
ACCEPTANCE OF PREMISES MEMORANDUM
This memorandum is being executed pursuant to the Commercial Lease
Agreement (the LEASE) executed on the _____ day of____________,1999, between
MEPC QUORUM PROPERTIES II INC., a Delaware corporation (LANDLORD), and
MANNATECH, INC., a Texas corporation (TENANT).
Landlord and Tenant hereby agree that:
1. Except for the Punch List Items (as shown on the attached Punch List),
Landlord has fully completed the construction work required under the
terms of the Lease and the Finish Plans attached thereto. Landlord will use
reasonable efforts to complete the Punch List Items within thirty (30) days
after the date hereof.
2. Tenant acknowledges that, subject to the Punch List Items, (i) it has
inspected and accepts the Premises, (ii) the buildings and improvements
comprising the same are suitable for the purpose for which the Premises are
leased, (iii) the Premises are in good and satisfactory condition, and (iv)
no representations as to the repair of the Premises, nor promises to alter,
remodel or improve the Premises which have been made by Landlord remain
unsatisfied.
3. The Rent Commencement Date of the Lease is the ____ day of ___________,
199___.
4. The expiration date of the Lease is the ____ day of__________, _____.
5. All capitalized terms not defined herein shall have the meaning assigned to
them in the Lease.
Agreed and Executed this ______day of ______________, 1998.
LANDLORD TENANT
MEPC QUORUM PROPERTIES II INC., MANNATECH, INC., a Texas corporation
a Delaware corporation a Texas corporation
By: By:
-------------------------- --------------------------------
Name: Name:
------------------------ ------------------------------
Title: Title:
----------------------- -----------------------------
By:
--------------------------
Name:
------------------------
Title:
-----------------------
EXHIBIT "F"
OMITTED
EXHIBIT "G"
Attached hereto are the site plans for the leased property.
