Exhibit 10.15
(PHOTO OF ONE HUNDRED RUPEES)
(Indian Characters) ANDHRA PRADESH
CO-DEVELOPER AGREEMENT
This Co-Developer Agreement is made and entered into at Hyderabad on 23rd day of
March, 2007 by and between:
ANDHRA PRADESH INDUSTRIAL INFRASTRUCTURE CORPORATION LIMITED, HYDERABAD, a
Government Company registered under the provisions of the Companies Act, 1956
and having its registered office at 0xx Xxxxx, Xxxxxxxxx Xxxxxxxx, Fateh Maidan
Road, Hyderabad - 500 004 (hereinafter referred to as 'DEVELOPER', which
expression shall unless repugnant to the context or meaning thereof include its
successors and assigns) of the ONE PART;
(APIIC Ltd. Stamp) (Virtusa (India) Private Limited Stamp)
(SEAL)
AND
VIRTUSA INDIA PVT LTD, also a Company incorporated under the provisions of the
Companies Act, 1956 and having its registered office at 3rd Floor, My Home
Tycoon, Begumpet, Hyderabad-500016 (hereinafter referred to as 'Co-developer',
which expression shall unless repugnant to the context or meaning thereof
include its successors and assigns) of the OTHER PART;
WHEREAS 'Developer' is the absolute owner and in possession of the vacant land
measuring 20.53 acres at survey No. 115/part, Nanakramguda Village,
Serilingampally Mandal, Rangareddy District, Andhra Pradesh. Pursuant to the
grant of requisite approval by the Board of Approval, Ministry of Commerce,
Government of India (hereinafter referred to as BOA), the 'Developer' is
developing an IT/ITES Special Economic Zone (hereinafter referred to as SEZ) at
the said land as per the Approval Letter No. F.2/108/2006, EPZ, dated 16.06.2006
attached herewith as APPENDIX A with 97% of the SEZ as processing zone. The SEZ
is fully described and delineated in the site plan attached as APPENDIX B to
this Agreement;
Whereas the Government of Andhra Pradesh ("GoAP") had earlier entered into a
Memorandum of Understanding (MOU) dated 09.12.2004 with the Co-developer
wherein the GoAP directed the Developer to allot land bearing No. 115 measuring
6.32 acres situated at Xxxxxxxxxxxx Xxxxxxx, Xxxxxxxxxxxxxxx Xxxxxx, X.X.
Xxxxxxxx, Xxxxxx Xxxxxxx (which is more fully described in the schedule
hereunder and hereinafter referred to as SECTOR A and shown in colour green in
the site plan annexed as APPENDIX B to this Agreement) to the Co-developer on
payment of the amount mentioned in MOU for the development of an IT Park.
2
Whereas prior to the commencement of construction by the Co-developer on the
Schedule Property, the Schedule Property was declared to be falling within the
SEZ.
AND WHEREAS since the Developer had already allotted the Schedule Property to
the Co-developer vide an Allotment Letter bearing No. Lr. No.
4042/PM(IPU)/APIIC/03 dated 15.01.2005 pursuant to the MOU, the 'Developer'
wishes to enter into an Lease Deed with the 'Co-developer' for development of
complete IT infrastructure on Sector A and for this purpose has granted a
perpetual lease of 99 years to 'Co-developer'.
Whereas The Developer has handed over the possession of Sector A to the Co
Developer to provide infrastructure facilities and undertake authorized
operations on Sector A.
AND WHEREAS 'Co-developer' will be responsible to apply to the BOA for being
approved as Co-developer in the SEZ for 'Sector A' under the provisions of the
Special Xxxxxxxx Xxxx'x Xxx, 0000 (hereinafter referred to SEZ Act) and the
Rules and Regulations framed there under.
AND WHEREAS the 'Developer' undertakes to get the SEZ notified under subsection
(1) of section 4 of the Special Economic Xxxxx Xxx, 0000 (28 of 2005) read with
rule 8 of the Special Economic Zones Rules, 2006.
AND WHEREAS 'Developer' and 'Co-developer' are desirous of reducing the
Co-Developer Agreement reached between them into writing.
3
NOW THIS AGREEMENT WITNESSETH AS UNDER:
1. 'Developer' and 'Co-developer' have agreed that the 'Co-developer' shall
have the sole responsibility (including through its agents, contractors and
subcontractors) for development of complete infrastructure for the
operation of IT/ITES company and carrying out the authorized operations in
'Sector A'. It shall be the responsibility of the 'Co-developer' for
getting approval of BOA for all the proposed activities as 'authorised
operations' and for which, the 'Developer' shall extend full co-operation.
2. The 'Developer' shall provide support infrastructure at its own cost such
as access road upto the periphery of 'Sector A', Power, water sewage upto
the 'Sector A' boundary as per ICT Policy 2005-2010. The 'Co-developer'
shall bear the cost of provision of power, water, sewerage and roads within
'Sector A' periphery and shall have to bear the cost of consumption of
water, power & sewerage. The 'Co-developer' shall pay the charges for
various servicing and common facilities and also for up-keep and
maintenance of Roads, water supply, drainage, sewage disposal, street
lights within Sector A to the administration or some other agency as the
case may be, failure in respect of which would entail the services being
disconnected.
3. The 'Developer' shall sign, without demur, such applications, no-objection
certificates or any documents prescribed by any statute / government
authority as may be required by the 'Co-developer' to obtain necessary
statutory approvals, permissions etc. to carry out its obligations in
accordance with the terms of this Agreement.
4
4. The 'Co-developer' shall invest an amount of at least Rs. 67.5 crores in
'Sector A' which will include investment in movable and immovable assets
like plant and equipment, hardware and software deployed in creation of
facilities/campus including lease premium of land and buildings inside
'Sector A' and shall build a minimum of 250,000 Sq. Ft. of plug and play
IT/ITES space in 'Sector A' from the date of commencement of construction
and the entire project shall be completed over a period of 3 years from the
date of commencement of construction.
5. The 'Co-developer' shall commence construction/site infrastructure work of
the project within 3 (three) months from the date of its official
designation as 'Co-developer' by the BOA or upon receiving all statutory
approvals to commence construction of the project, which ever is later.
6. The 'Co-developer' shall have the sole and exclusive right with respect to
'Sector A' portion of the SEZ including but not limited to all the
developments thereon and to all revenues including advances and deposits
etc. and 'Developer' shall have no rights or claim whatsoever on the same.
The Co-developer shall be entitled to use the IT infrastructure project on
completion and take all further steps necessary for the use of the IT
Infrastructure project or units.
7. The Co-developer shall be responsible for obtaining all requisite
sanctions, approvals, clearance and permissions for development of Premises
and construction of the infrastructure, building or erection
5
of any structure in 'Sector A' and shall observe and conform to all laws,
rules, regulations and byelaws of the state/ local authority concerned and/
or any other statutory regulations in force including but not limited to
conditions under the various environment related legislation, including,
without limitation, as prescribed by the Pollution Control Board, and the
terms and conditions of the Lease Agreement relating to the said
construction / erection, at its own cost and expense.
8. All costs, expenses, charges, etc. for the construction of the
infrastructure, building or erection of any structure on Sector A and all
matters connected with and incidental thereto, including expenses for
preparation, submission and obtaining approval and sanction for the
building plan, obtaining the occupation certificate and all other
permissions and approvals shall be borne exclusively by the Co-developer.
9. The Co-developer shall be solely responsible for compliance of and for
discharging all obligations to or in connection with its employees, agents
or contractors for payments including payment of wages / salaries,
providing all amenities and benefits that may be required under the law for
the time being in force, for any statutory liability arising out of
employment or non-employment and for the safety and security of all
personnel engaged and materials used by the Co-developer in the
development of 'Sector A' and construction of infrastructure, building or
erection of the structure and the Developer shall in no way be concerned
with the same.
6
10. The 'Co-developer' shall stay invested in the project till the completion
of the project and any change in the said status during such period shall
be made with prior approval of IT & C Department, GoAP and the 'Developer',
which approval will not be unreasonably withheld.
11. The 'Developer' shall not be responsible to any customers, vendors and any
other parties in relation to 'Sector A' of SEZ and the 'Co-developer' shall
keep 'Developer' indemnified against any claim(s) with reference to 'Sector
A' unless the same is a result of any direct/indirect act of the
'Developer'. The 'Developer' shall indemnify and keep indemnified the
'Co-developer' in respect of any claim or liability incurred or suffered by
the 'Co-developer' as a result of a breach of the terms of this Agreement
by the 'Developer'.
12. Part or all of any clause of this Agreement that is illegal, unlawful,
unenforceable either at the inception of this Agreement or by virtue of any
new laws, maybe severed, at the time of the same coming into effect or at
the time of bringing of the same to the notice of the other party, from
this Agreement and does not affect the continued operation of the remaining
provisions of this Agreement.
13. The failure of a party at any time to require full or partial performance
of any provision of this Agreement does not affect in any way the full
right of that party to require that performance subsequently. The waiver by
any party of a breach of a provision of this Agreement is not deemed to be
a waiver of all or part of that provision or of any other provision or of
the right of that party to avail
7
itself of its rights subsequently. Any waiver of a breach of this Agreement
must be in writing signed by the party granting the waiver, and is
effective only to the extent specifically set out in that waiver.
14. The expression 'FORCE MAJEURE' shall mean and include:
a. war, hostilities (whether war declared or not) invasion, act of
foreign enemies, rebellion, revolution, insurrection, military or
usurped power, civil war, terrorism, riot and disorders, strike,
lockout, labour unrest or other industrial disturbances
(affecting the performance of this Agreement).
b. Ionizing radiation or contamination by radioactivity from any
nuclear waste from the combustion of nuclear fuel, radioactive
toxic explosive, or other hazardous properties of any explosive,
nuclear assembly or nuclear component thereof.
c. Pressure waves caused by aircraft or other aerial devices
traveling at sonic or at supersonic speeds;
d. earthquake, floods, subsidence, lightning or any operation of the
forces of nature;
Any other event such as changes in market conditions which impact the
demand for built up office space and thus impair the ability of the
Co-Developer to fulfill the obligations mentioned herein etc, which
8
the Co-Developer could not reasonably be expected to control (but shall not
include any event caused by failure to observe good construction, operation
or maintenance practice nor any event caused by negligence in the provision
of adequate supervision) which significantly delays or renders the
agreement incapable of being performed, and which, even by the exercise or
due diligence neither party is able to overcome;
No party shall be liable to the other if, and to the extent, that the
performance or delay in performance of any of its obligations under this
Agreement is prevented, restricted, delayed or interfered as a result of a
Force Majeure event. The party claiming the Force Majeure event shall
notify the other party in writing and provide full particulars of the cause
or event and the date of first occurrence thereof, as soon as possible
after the event and also keep the other party informed of any further
developments. The parties shall use their best efforts to remove the cause
of non-performance and shall resume performance hereunder with utmost
dispatch when such cause or event is removed. If the Force Majeure
continues for a continuous period of three (3) months, the parties shall
mutually discuss the future course of action available to them to resolve /
rectify the Force Majeure event. Further, upon the happening of a Force
Majeure event, the time period for completion of the project as set out
hereinabove shall get automatically extended by the period for which the
Force Majeure event subsists.
15. The 'Developer' represents and warrants that there is no restriction on it
entering into this Agreement with the 'Co-developer. Further,
9
the representations and undertakings of the 'Developer' as set out in the
Recitals to this Agreement shall form an integral part of this Agreement.
16. A notice required or authorised to be given or served upon a party pursuant
to this Agreement must be in writing in the English language and may be
given or served by facsimile, prepaid post or delivered by hand to that
party at the address of the party as specified herein above or such other
address or facsimile number as the party may have notified in writing to
the other party or parties:
17. This Agreement is governed by the laws of India and Andhra Pradesh as the
case may be. Subject to Clause 19, each party irrevocably submits to the
jurisdiction of the courts of Hydrabad, Andhra Pradesh.
18. No amendment to this Agreement has any force unless it is in writing and
signed by the parties to this Agreement.
19. In the event the disputes or differences are not resolved amicably, the
same shall be referred to arbitration in accordance with The Indian
Arbitration and Conciliation Act, 1996 or its successor legislation and
shall be conducted in Hyderabad. The Arbitral Tribunal shall consist of
three members, one each to be nominated by each Party and the Umpire to be
nominated by the two arbitrators. The decision of the arbitrators shall be
final and binding upon the parties. Any reference under this clause shall
be deemed to be a reference to arbitration within the meaning of the Indian
Arbitration and Conciliation Act, 1996 or its successor legislation.
10
Sector A
Immovable Property bearing No. 115 Part admeasuring 6.32 acres situated at
Xxxxxxxxxxxx Xxxxxxx, Xxxxxxxxxxxxxxx Xxxxxx, X.X. Xxxxxxxx, Xxxxxx Xxxxxxx and
bounded on the:
East by: Proposed 00.XX Wide Road
West by: Private Lands
North by: Proposed 00.XX Wide CDA M.P. Road
South by: Xxxx Xx.0
IN WITNESS WHEREOF THE PARTIES HAVE SIGNED THIS AGREMENT ON THE DAY, DATE AND
MONTH MENTIONED ABOVE.
'DEVELOPER' 'CO-DEVELOPER'
(APIIC Ltd. Stamp) (Virtusa (India) Private Limited Stamp)
WITNESSES:
1.
2.
(SEAL)
11
APPENDIX - A
(SEAL) (STAMP)
No. F.2/108/2006-EPZ
Government of India
Ministry of Commerce & Industry
Department of Commerce
(SEZ Section)
...
Dated the 16th June, 2006
To,
The Developer,
Andhra Pradesh Industrial Infrastructure Corpn Ltd (APIIC),
6th Floor, Xxxxxxxxx Bhavan, Fateh Maidan Road.
Basheerbagh, Hyderabad 500 004 (AP).
Subject: Setting up of a sector-specific Special Economic Zone for IT/ITES
sector at Nanakramguda Village, Serilingampally Mandal,
Rangareddy Dist, Andhra Pradesh - Reg
Sir(s),
With reference to your above mentioned application, Government of India is
pleased to grant formal approval to your proposal for development, operation and
maintenance of a Special Economic Zone (SEZ), as per details given below:-
I. PROPOSAL and PROJECT DETAILS:- To set up a sector-specific Special Economic
Zone for IT/ITES sector over an area of 20.53 hectares at Xxxxxxxxxxxx Xxxxxxx,
Xxxxxxxxxxxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, Xxxxxx Xxxxxxx
II. DEVELOPER:- M/s. Andhra Pradesh Industrial Infrastructure Corpn Ltd (APIIC)
III. General Conditions:
(i) The Developer shall develop, operate and maintain the Special Economic
Zone in terms of the Special Economic Xxxxx Xxx, 0000 and the rules
made there-under.
(ii) The Developer shall execute Bond-cum-Legal Undertaking as required
under rules 12 and 22 of the Special Economic Zone Rule, 2006 for the
authorised operations.
(iii) The Developer shall obtain the required approval from various
statutory authorities under relevant statutes and regulations of the
Government of India and the State Government and local bodies.
(iv) The Developer shall make adequate provision for rehabilitation of the
displaced persons.
(v) The project shall be implemented and operated in terms of the Special
Economic Xxxxx Xxx, 0000 and the rules and orders made there-under.
(vi) The Developer shall conform to the environmental requirements.
(vii) The Developer shall abide by the local laws, rules, regulations or
bye-laws in regard to area planning, sewerage disposal, pollution
control, labour laws and the like as may be locally applicable.
(viii) The Developer shall raise the required funds for the project.
External commercial borrowing, if any, will be as per the guidelines
of the Ministry of Finance, Department of Economic Affairs, Government
of India, New Delhi.
(ix) This approval is valid for a period of three years within which time
the Developer shall implement the project. The project implementation
progress report will be submitted to Government of India every six
months.
(x) This approval is liable to be suspended in case of violation of any of
the terms and conditions stipulated herein.
(xi) The operation and maintenance of the facilities will be made as per
the standards specified in the proposal and to the satisfaction of the
users.
(xii) The Developer shall maintain adequate manpower to provide the
facilities.
(xiii) The user charges will be finalized in consultation with the
Development Commissioner and the users. This shall be subject to
revision as per the agreed terms.
(xiv) The Developer shall obtain the approval of Board for specific
activities proposed to be undertaken for development, operation and
maintenance of Special Economic Zone. Based on the activities approved
by the Board, the Developer shall be entitled for duty free import or
domestic procurement of goods for the approved activities under rules
10 after the Special Economic Zone has been notified.
(xv) The authorized operations shall be carried out in terms of the
parameters laid down in the Special Economic Xxxxx Xxx, 0000 and the
Rules and orders made there-under and in accordance with the proposal
approved herein.
(xvi) No duty free goods shall be available for personal use of, or
consumption by officials, workers, staff or owners of the Unit or
Developer.
(xvii) Normally, no extension of validity period of three years for
implementation of the project will be considered. Any request,
however, may be considered by the Board, on merits. Such request shall
be submitted to the Government six months before expiry of the
approval period.
(xviii) The developer shall construct a minimum built up processing area of
One Lakh square meters.
2. This approval shall be also subject to other conditions as approved by the
Board.
3. The Developer may convey acceptance of all the terms and conditions indicated
above within thirty days from the date of issue of this letter. All future
correspondence may be addressed to the Director (SEZ), Department of Commerce,
Udyog Bhavan, New Delhi-11.
4. The Developer may send exact details of the area along with a map indicating
the Special Economic Zone area certified by the District Revenue Authorities for
notification in the Gazette of India.
5. The Developer shall furnish to the Development Commissioner. Visakhapatnam
Special Economic Zone returns on import, procurement and utilization of goods,
as provided for under the Special Economic Zone Rules, 2006.
Yours faithfully,
/s/ Xxxxxxxx Xxxx
----------------------------------------
16.6.06
(XXXXXXXX XXXX)
Director
Tel. (000) 0000 0000
Email: x.xxxx@xxx.xx
Copy to:
1. Central Board of Excise and Customs (Shri A.P. Sudhir, Member
(Customs), Xxxxxxxxxx xx Xxxxxxx, Xxxxx Xxxxx, Xxx Xxxxx.
2. Central Board of Direct Taxes (Shri Xxxxxx Xxxx, joint Secretary
(TPL-II)), Department of Revenue, North Block, New Delhi.
3. Ministry of Finance (Shri Xxxxxx Xxxxx, Joint Secretary), Banking
Division, Department of Economic Affairs.
4. Department of Industrial Policy and Promotion (Shri Xxxxx Xxxxx, Joint
Secretary).
5. Ministry of Science and Technology (Shri X.X.Xxxxx, Adviser),
Technology Bhavan, Mehrauli Road, New Delhi.
6. Ministry of Small Scale Industry (Shri Xxxxxxxxx Xxxxxx, Development
Commissioner), Xxxxxx Bhavan, New Delhi.
7. Ministry of Home Affairs (Shri X.X. Xxxxx, Joint Secretary), North
Block, New Delhi
8. Ministry of Defence (Shri Xxxxx Xxxxx, Joint Secretary (Coordination).
9. Ministry of Environment and Forests (Shri X. Xxxxxxxxxxxx, Joint
Secretary), Xxxxxxxxxxx Xxxxxx, XXX Xxxxxxx, Xxx Xxxxx - 3.
10. Legislative Department (Xx. X.X Xxxxxx, Joint Secretary and
Legislative Counsel).
11. Ministry of Overseas Indian Affairs (Shri X. Xxxxxxxxxx, Joint
Secretary (FS), Akbar Bhawan, Chankyapuri, New Delhi.
12. Department of Urban Affairs, Town Country Planning Organisation, (Shri
K.T. Gurumukhi, Chief Planner), Vikas Bhavan (E-Block), X.X. Xxxxxx,
Xxx Xxxxx.
00. Director General of Foreign Trade (Shri X.X. Xxxxxx, DG), Department
of Commerce, Udyog Bhavan, New Delhi.
14. Development Commissioner, Visakhpatnam Special Economic Zone,
Visakhapatnam.
15. Govt. of Andhra Pradesh (Smt K. Xxxx Xxxxxx, Secretary, Information
Technology and Communication), 'D' Block, Room No. 431-A, A.P.
Secretariat, Hyderabad - 500022
Copy for information to: PPS to SS (GKP)/ PPS to JS (JD)/DS (RGS).
APPENDIX-B
(PROPOSED LAY OUT PLAN OF I.T. PARK AT NANAKRAMGUDA)
WITNESS
1)
2)
(SEAL)
XXXXXX-X
XXXX XXXX XX XXXX XX-00, XX XX.XX. 115/P ON I.T. PARK, SITUATED AT
NANAKRAMGUDA(V) R. R. DIST. A.P. ALLOTTED TO M/S. VIRTUSA (INDIA) PVT. LTD.
AREAS:- REF:-
PLOT AREA: 25,577.04 SQ. MTS./ INCLUDED: ___________________________
AC.6.32
BOUNDARIES:-
NORTH: PROP. 45.0M WIDE CDA M.P. ROAD
SOUTH: PLOT NO. 9
EAST: PROP. 18.0M WIDE ROAD
WEST: PRIVATE LANDS.
(PROPOSED LAY OUT PLAN OF I.T. PARK AT NANAKRAMGUDA)
WITNESS
1)
2)
(SEAL)
PHOTOGRAPHS AND FINGERPRINTS AS PER SECTION 32A OF REGISTRATION ACT, 1908
FINGER PRINT IN NAME & PERMANENT POSTAL
BLACKINKLEFT PASSPORT SIZE ADDRESS OF PRESENTANT/OWNER
THUMB PHOTOGRAPH /DEVELOPER
--------------- ------------- ----------------------------------------------
(OVAL) (BOX) DEVELOPER
1. APIIC LIMITED
0XX XXXXX XXXXXXXXX XXXXXX,
XXXXXXXXXXX,
XXXXXXXXX - 500 004.
REP. BY. PROJECT MANAGER (IPU)
SRI D. XXXXXXXXXXXXX XXX
S/O X.XX. B. XXXXXX XXX
(OVAL) (BOX) CO-DEVELOPER
2 M/s. Virtusa (India) Private Limited,
3rd Floor, MyHome Tycoon,
Begumpet, Hyderabad-500 016.
XXX.XX: FINANCIAL CONTROLLER
SRI M. HARI RAJU,
S/O M. XXXX XXXX
(OVAL) (BOX) SPL. POWER OF ATTORNEY TO (1)
SPA NO.93/2003, DT. 27.6.2003
3. SRI C. XXXX XXXXXXXXXXXX
S/O XXXXXXX XXXXXXXX
Manager (Development),
APIIC,, Basheerbagh
Hyderabad - 500 004
SIGNATURE OF WITNESSES
1
2
(PHOTO OF ONE HUNDRED RUPEES)
(Indian Characters) ANDHRA PRADESH
LEASE DEED
THIS LEASE DEED ("DEED") IS MADE AND EXECUTED AT HYDERABAD ON THIS 26TH DAY OF
MARCH 2007.
BY AND BETWEEN
ANDHRA PRADESH INDUSTRIAL INFRASTRUCTURE CORPORATION LIMITED, Hyderabad, a
Government Company registered under the provisions of the Companies Act, 1956
and having its registered office at 0xx Xxxxx, Xxxxxxxxx Xxxxxxxx, Fateh Maidan
Road, Hyderabad - 500 004 represented herein by Mr. D. Xxxxxxxxxxxxx Xxx,
Authorised Signatory (hereinafter referred to as APIIC/LESSOR', which expression
shall unless repugnant to the context or meaning thereof include its successors
and assigns) of the ONE PART;
(APIIC Ltd. Stamp) (Virtusa (India) Private Limited Stamp)
(SEAL)
AND
VIRTUSA (INDIA) PRIVATE LIMITED, a company registered under the Companies Xxx,
0000, having its Registered Office at 0xx Xxxxx, Xx Xxxx Xxxxxx, Xxxxxxxx,
Xxxxxxxxx-000000, represented herein by its Financial Controller, Mr. M, Hari
Raju, vide resolution passed at the meeting of the Board of Directors/
Authorization dated ________________________________ (hereinafter referred to as
"VIRTUSA/LESSEE", which term shall unless the context requires otherwise include
its successors in office and assigns) of the OTHER PART
WHEREAS:
(1) 'Lessor' is the absolute owner and possessor of the vacant land measuring
50.73 acres at survey No. 115/part, Nanakramguda Village, Serilingampally
Mandal, Rangareddy District, Andhra Pradesh. Pursuant to the grant of
requisite approval by the Board of Approval, Ministry of commerce,
Government of India (hereinafter referred to as BOA), the
Lessor/'Developer' is developing an IT/ITES Special Economic Zone
(hereinafter referred to as SEZ) at the said land as per the Approval
Letter No.F.2/108/2006-EPZ dated 16.6.2006 attached herewith as APPENDIX A
with 97% of the SEZ as processing zone. The SEZ is fully described and
delineated in the site plan attached as APPENDIX B to this Deed;
(2) On the request of the Lessee, the 'Lessor' is agreeable to lease out 6.32
acres of Land forming part of 50.73 acres at survey No. 115/part,
Nanakramguda Village, Serilingampally Mandal, Rangareddy District, Andhra
Pradesh morefully described in the Schedule hereunder and hereinafter
referred to as SECTOR A shown in colour green in the site plan APPENDIX B
to this Lease Deed on lease for 99 years to the 'Lessee' for development of
complete IT infrastructure within the periphery of 'Sector A' as a
co-developer for 'Sector A' portion of the SEZ.
(3) The "Lessee" has agreed to take on lease 'Sector A' portion of SEZ subject
to the terms and conditions hereafter appearing and to become a
co-developer for the purpose of providing infrastructure facilities and
undertake authorized operations in 'Sector A' of SEZ.
(4) The 'Lessee' will be responsible to apply to the BOA for being approved as
Co-developer in the SEZ for 'Sector A' under the provisions of the Special
Xxxxxxxx Xxxx'x Xxx, 0000 (hereinafter referred to SEZ Act) and the Rules
and Regulations framed there under. 'Lessor' shall assist 'Lessee' in
obtaining such approval by signing the required consent letter, documents
etc.
(5) The 'Lessor' undertakes to get the SEZ notified under subsection (1) of
section 4 of the Special Economic Xxxxx Xxx, 0000 (28 of 2005) read with
rule 8 of the Special Economic Zones Rules, 2006.
(6) Parties had entered into a MOU dated 9th December, 2004 ("MOU") and an
Agreement to Sale dated 28th June, 2006 ("Agreement to Sale") containing
the
2
terms and conditions relating to the allotment and usage of Sector A, which
form part of this Deed as specified in the relevant clause below.
NOW THIS LEASE DEED WITNESSETH AS FOLLOWS:
1. GRANT OF LEASE & CONSIDERATION
1.1 In consideration of the payment of Lease Premium amounting to Rs.
2,29,19,190 (Rupees Two Crores Twenty Nine Lakhs Nineteen Thousand One
Hundred and Ninety only) details of which are provided in Clause 1.2
below and yearly rentals by the Lessee to the Lessor and the
observance of terms and conditions hereinafter contained by the
Lessee, the Lessor hereby demises to the Lessee and the Lessee hereby
takes on lease, 'Sector A' as detailed in Appendix B, for a period of
99 years commencing from 26/3/07 and ending on 25/3/2106 ("TERM"),
subject to the conditions stipulated hereunder.
1.2 In terms of Clause 3(a) and 3(b) of the MOU and Clause I of the
Agreement to Sale, Lessee is entitled to an employee related rebate
cum reduction of an amount equivalent to Rs.2,29,19,190 (Rupees Two
Crores Twenty Nine Lakhs Nineteen Thousand One Hundred and Ninety
only). It is further clarified that IT & C Department has confirmed
that Lessee has employed 1247 eligible employees vide Lr.No.1863/IT
&C/2004 dt. 18.03.2005 and that the Lessee has to further employ a
minimum of 857 employees to claim full rebate on Lease Premium. To
that extent the Lessee has furnished a Bank Guarantee No.
021GTO2061170001 dt.27.4.2006 for Rs.93,35,500 (amount balance
associated with remaining 857 eligible employee obligation) of HDFC
Bank Limited, Hyderabad which is valid up to 27.4.2009. Lessee shall
pay the annual lease rent of Rs.100/-(Rupees one hundred only) per
year for 99 years on first of January of each year at the office of
the Lessor.
1.3 This lease shall be subject to Lessee getting the requisite approval
from the Board of approval for becoming a co-developer of the 'Sector
A' portion of SEZ. In case such status/permission is not granted
within a period of 12 months from the date of this deed, whichever is
earlier, this lease shall stand terminated from the date of refusal by
the concerned authorities or 12 months whichever is earlier and the
terms of the MOU and the Agreement to Sale shall prevail and be
binding on Parties. Forthwith upon such termination, the Lessor shall
refund all amounts whatsoever paid by the Lessee to the Lessor under
this deed.
1.4 The period of Lease shall be Ninety Nine (99) years and may be renewed
as mutually agreed upon by the Parties on the same terms and
conditions.
1.5 The Lessor hereby represents and warrants to the Lessee that (a) it is
the sole, legal and absolute owner of 'Sector A' with uninhibited
rights of alienation over the same and no others whomsoever have any
manner of subsisting rights, title or interest or have or will have
any claims, in respect
3
of 'Sector A', and (b) 'Sector A' can be used in all respects for the
purposes contemplated hereunder.
1.6 The Lessee may exercise the option to purchase 'Sector A' at any time
during the tenure of this Lease Deed, if the same is permitted under
SEZ Act, 2005. The Lessor undertakes that in the event the Lessee
exercises its option to purchase 'Sector A', it shall allot the same
on outright sale basis in favour of the Lessee as per the terms and
conditions contained in the MOU and the Agreement to Sale.
2. COVENANTS BY THE LESSOR
The Lessor hereby covenants that:
2.1 Lessor will gel the SEZ notified under subsection (1) of section 4 of
the Special Economic Xxxxx Xxx, 0000 (28 of 2005) read with rule 8 of
the Special Economic Zones Rules, 2006.
2.2 The 'Lessor' shall provide support infrastructure at its own cost such
as access road upto the periphery of 'Sector A', Power, water sewage
upto the 'Sector A' boundary as per ICT Policy 2005-2010. The 'Lessee'
shall bear the cost of provision of power, water, sewerage and roads
within 'Sector A' periphery and shall have to bear the cost of
consumption of water, power & sewerage. The 'Lessee' shall pay the
charges for various servicing and common facilities and also for
up-keep and maintenance of Roads, water supply, drainage, sewage
disposal, street lights to the administration or some other agency as
the case may be, failure in respect of which would entail the services
being disconnected.
2.3 The 'Lessor' shall facilitate development of infrastructure for entire
SEZ in an integrated manner in consultation with the 'Lessee' and
other co-developers and shall provide a mutually agreed integrated
infrastructure scheme in SEZ so that the 'Lessee' could provide all
infrastructure services, within 'Sector A' in consonance with the
integrated infrastructure scheme in SEZ.
2.4 The Lessor shall ensure that the Lessee shall peacefully and quietly
use and enjoy, in accordance with the terms of this Lease Deed, the
'Sector A', without interruption or disturbance by the Lessor or any
person lawfully or otherwise claiming by or through or under the
Lessor during the currency of this Deed.
2.5 The Lessor shall sign, without demur, such applications, no-objection
certificates or any documents prescribed by any statute / government
authority as may be required by the Lessee to obtain necessary
statutory approvals, permissions etc. to carry out its use of 'Sector
A' in accordance with the terms of this Deed.
2.6 The 'Lessee' is entitled to seek various approvals and clearances in
relation to the development and construction of infrastructure within
4
'Sector A' and to create mortgage, land in 'Sector A' (with prior
written consent of "Lessor', which shall not be unreasonably withheld)
in favor of the financial institutions/banks for extending loans and
other facilities to the 'Lessee' in relation to the co-development of
'Sector A'. The Lessee shall be entitled to create a mortgage or other
charge whatsoever, over (a) its rights under this Lease Deed, and/or
(b) its rights over the infrastructure and/or the buildings in 'Sector
A', without any restriction whatsoever, with prior written consent of
Lessor (which shall not be unreasonable withheld).
2.7 The Lessor agrees to consider any successor, transferee or assignee of
the Lessee including by reason of any scheme of reconstruction,
merger, demerger and any other change may be substituted in place of
the Lessee subject to the terms of this Lease Deed and the provisions
of the Special Xxxxxxxx Xxxx'x Xxx, 0000 (hereinafter referred to SEZ
Act) and the Rules and Regulations framed there under.
2.8 The Lessor shall not alienate, encumber or transfer any rights or
interest whatsoever in 'Sector A', in favor of any person during the
period of lease subject to clause 2.6 mentioned hereinabove.
3. DEVELOPMENT OF 'SECTOR A'
3.1 Lessee shall have the sole responsibility (including through its
agents, contractors and subcontractors) for development of complete
infrastructure for operation of IT/ITES companies and carrying out the
authorized operations in 'Sector A'.
3.2 Each Party hereby for itself and all persons deriving or claiming any
right, title or interest under it (collectively the "Indemnitor")
covenant, agree and undertake with the other Party its successors and
all persons claiming under it (collectively the "Indemnitee") that the
Indemnitor shall and will from time to time and at all times
throughout hereafter save harmless, indemnify and keep indemnified the
Indemnitee and their respective estates and effects against all
actions, suits, proceedings, claims, demands, costs, charges,
expenses, damages, penalties or payments that may be taken or made by
any authority or by anyone whomsoever for any breach by the Indemnitor
or by any one whomsoever under the instructions of an Indemnitor or on
their behalf or for them of any provisions of this Deed.
4. COVENANTS OF THE LESSEE
The 'Lessee' shall invest a minimum amount as agreed upon in Clause 2 (d)
of the MOU in 'Sector A' which will include investment in movable and
immovable assets and construction buildings, plant and equipment, hardware
and software deployed in creation facilities/campus inside 'Sector A' and
shall build a minimum of 2,50,000 Sq. Ft. of IT/ITES space in 'Sector A' in
phases, and the entire project shall be completed over a period of 3 years
from the date of obtaining possession of 'Sector A'. The Lessee shall
ensure employment generation as agreed upon in the MOU.
5
4.1 The 'Lessee' shall commence construction/site infrastructure work of
the project within 6 months from the date of taking possession of
'Sector A' or upon receiving all statutory approvals to commence
construction of the project, which ever is later. It is hereby agreed
that as of the date of this Deed, Lessee is in full compliance with
this Section.
4.2 The 'Lessee' shall utilize 'Sector A' for the purpose for which it is
leased i.e., for IT or ITES purposes and not for any other purpose.
4.3 The 'Lessee' undertakes to inform 'Lessor' about the details of
Finance(s) raised (if any) on the security of 'Sector A', from time to
time till the Loan(s) is/are re-paid to the financial agencies.
4.4 The Lessee shall have (a) the right to sub-lease / license out 'Sector
A' and any development / infrastructure constructed thereon either in
whole or in part(s) to one or more units and shall keep the Lessor
informed in advance.
4.5 The Lessee shall pay all Taxes, charges, rates, and outgoings of
whatsoever in respect of the Sector A premises to the competent
authorities.
4.6 The Lessee shall insure all the buildings together with all fittings &
fixtures, machines etc. with any Insurance Company for loss due to
fire, earthquake, storm, flood etc. through out the period of lease.
5. STAMP DUTY & REGISTRATION
All expenses with respect to execution and registration of this Lease
Deed shall be paid by the Lessee including stamp duty, registration
charges or any other statutory fee or charges required to be paid
under applicable law to complete the transaction envisaged under this
Lease Deed. Subject to the terms hereof, all formalities relating to
registration of this Lease Deed shall be commenced forthwith upon
execution of this Deed, and shall in any event be completed within a
period of _______________ days from the date of execution of this
Lease Deed.
6. MISCELLANEOUS PROVISIONS
6.1 Time is of the essence with respect to all of the terms and conditions
of this Lease Deed.
6.2 The parties have agreed that the Deed shall not alter, amend or
terminate any of the provisions of the Agreement to Sale or the MOU.
In the event of the termination of the Deed for any reason whatsoever
including breach of the Deed, the parties shall revert to the
Agreement to Sale/MOU and the terms of the Agreement to Sale/MOU shall
be binding on the Parties. Further, in case of a conflict between the
terms of the Deed and the Agreement to Sale, the terms of the
Agreement to Sale shall prevail.
6
6.3 Failure by either Party to enforce any provision of this Lease Deed
shall not constitute a waiver or affect a respective Party's right to
require the future performances thereof, nor shall either Party's
waiver of any breach of any provision of this Lease Deed constitute a
waiver of any subsequent breach or nullify the effectiveness of any
provision.
Any delay in completion of the project on any reason, during the
period of lease, shall be treated as significant event of default of
the Lessee under this lease deed, leading to the termination of this
lease deed. In case of such a delay, the 'Lessor' shall notify the
'Lessee' of such default in writing and shall call upon the 'Lessee'
to rectify the same within a period of 180 (one hundred eighty) days
from the date of Lessor's written notice to Lessee. In the event such
default is not rectified within such stipulated time, the 'Lessor' is
entitled terminate this lease deed forthwith.
6.4 In the event that any provision of this Lease Deed shall be held
invalid as contrary to any law, statute or regulation in that regard,
the validity of any other provision of this Lease Deed shall not be
affected and each and every provision shall be severable from each and
every other.
6.5 The Lessor and Lessee shall not be liable as per MOU, the Allotment
Letter, and this Deed for any delay or default in compliance of any of
the terms thereof, which is solely attributable to causes beyond their
control. If delay is caused in such an event, the period for
compliance shall be extended by the period of such delay. If, due to
such causes, either party, using reasonable, good faith efforts, is
not able to implement the provisions of the MOU, the Allotment of the
Schedule Land and this Deed, then neither party shall be liable to the
other and in such an event Lessor shall refund to Lessee all amounts
paid to the Lessor in connection with the Schedule Land and the
parties shall resume status quo ante as per APIIC allotment
regulations.
6.6 The Lessor and Lessee are independent contractors, independent of one
another and neither has the authority to bind the other to any third
party or otherwise to act as the representative of the other unless
otherwise expressly agreed to in writing by both parties hereto.
6.7 Notice under this Lease Deed will be in writing and will, for all
purposes, be deemed to have been fully given and received when
actually received and they will be sent by registered or certified
mail, return receipt request, postage prepaid, (unless otherwise
provided) properly addressed, to the respective parties hereto at the
following addresses, or at such other address for either party as may
be specified by the such party to such purpose, or by telefax and
confirmed by hardcopy mailed to the recipient:
The LESSOR APIIC LTD
[4th Floor, Xxxxxxxxx Bhavan, Basheer
Bagh, Hyderabad - 500 004
Attention: D. Xxxxxxxxxxxxx Xxx,
7
Project Manager (IPU),
Facsimile Number: 040 - 23240205
LESSEE VIRTUSA INDIA PRIVATE LIMITED
0xx Xxxxx, Xx Xxxx Xxxxxx,
Xxxxxxxx, Xxxxxxxxx-000000
Attention: Xx. Xxxx Xxxx
Facsimile Number: 000-0000 0000
6.8 If any dispute or difference shall at any time arise between the
Parties to this Lease Deed or under any clause or their respective
rights, claims or liabilities hereunder or otherwise in any manner
whatsoever, in relation to or arising out of or concerning this Lease
Deed, the Parties shall promptly and in good faith negotiate with a
view to arrive at an amicable resolution and settlement. In the event
no amicable resolution or settlement is reached within a period of 30
days from the date of commencement of discussions, subject to the
provisions of SEZ Act and without in any manner affecting the rights
of the authorities under the said Act, such disputes and/or
differences shall be referred to arbitration whereby each Party hereto
shall appoint one arbitrator and the two arbitrators so appointed
shall appoint a third arbitrator to act as the presiding arbitrator.
If the two arbitrators fail to appoint a third arbitrator, then the
third arbitrator shall be appointed as per the Arbitration and
Conciliation Act, 1996 and any amendments or modifications thereto.
The arbitration proceedings shall be held in Hyderabad in accordance
with the provisions of the Arbitration and Conciliation Act, 1996 and
the findings of the arbitrator(s) shall be final and binding on the
Parties. The proceedings shall be conducted in the English language.
During the period of any dispute under this Agreement, through the
date of final adjudication or settlement, as the case may be, neither
party shall have the right to terminate this Agreement.
6.9 The Parties shall bear the cost of appointing their respective
arbitrators and the costs incurred towards the appointment of the
third arbitrator shall be borne by both the Parties equally.
6.10 This Lease Deed shall be governed by Indian Law and subject to Clause
6.10 above, the courts of law in Hyderabad will have exclusive
jurisdiction in any matter arising from or relating to this Deed to
the exclusion of all other Courts that may have had jurisdiction in
the matter.
6.11 Counterparts: This Lease Deed has been executed in duplicate, each of
which shall be deemed an original but all of which together shall
constitute but one and same instrument.
8
SCHEDULE PROPERTY - Sector A
District: Ranga Reddy Mandal: Serilingampally
Village: Nanakramguda Municipality: Serilingampally
Land measuring 6.32acres, situated in Survey No. 115/Part of Nanakramguda
Village Serilingampally Mandal, R R District
East by: Proposed 18.0M Wide Road
West by: Private Lands
North by: Proposed 45.0M Wide CDA M.P.Road
South by: Xxxx Xx.0
IN WITNESS WHEREOF, the parties hereto above have caused this Deed to be
executed as on the day mentioned herein above.
SIGNED AND DELIVERED by the within (APIIC Ltd. Stamp)
named LESSOR (ANDHRA PRADESH
INDUSTRIAL INFRASTRUCTURE CORPORATION
LIMITED) through its Authorized
Signatory
Mr. SIGN & DATE
---------------------------------
in the presence of
Mr. SIGN & DATE
--------------------------------
SIGNED AND DELIVERED by the (Virtusa (India) Private
within named LESSEE (VIRTUSA INDIA Limited Stamp)
PRIVATE LIMITED) through its authorized
signatory;
Mr. SIGN & DATE
---------------------------------
in the presence of
Mr. SIGN & DATE
---------------------------------
(SEAL)
9
APPENDIX - A
(SEAL) (STAMP)
No. F.2/108/2006-EPZ
Government of India
Ministry of Commerce & Industry
Department of Commerce
(SEZ Section)
Dated the 16th June, 2006
To,
The Developer,
Andhra Pradesh Industrial Infrastructure Corpn Ltd (APIIC),
0xx Xxxxx, Xxxxxxxxx Xxxxxx, Xxxxx Xxxxxx Xxxx,
Xxxxxxxxxxx, Hyderabad 500 004 (AP).
Subject: Setting up of a sector-specific Special Economic Zone for IT/ITES
sector at Nanakramguda Village, Serilingampally Mandal,
Rangareddy Dist, Andhra Pradesh - Reg
Sir(s),
With reference to your above mentioned application, Government of India is
pleased to grant formal approval to your proposal for development, operation and
maintenance of a Special Economic Zone (SEZ), as per details given below:-
I. PROPOSAL and PROJECT DETAILS:- To set up a sector-specific Special Economic
Zone for IT/ITES sector over an area of 20.53 hectares at Xxxxxxxxxxxx Xxxxxxx,
Xxxxxxxxxxxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, Xxxxxx Xxxxxxx
II. DEVELOPER:- M/s. Andhra Pradesh Industrial Infrastructure Corpn Ltd (APIIC)
III. General Conditions:
(i) The Developer shall develop, operate and maintain the Special Economic
Zone in terms of the Special Economic Xxxxx Xxx, 0000 and the rules
made there-under.
(ii) The Developer shall execute Bond-cum-Legal Undertaking as required
under rules 12 and 22 of the Special Economic Zone Rule, 2006 for the
authorised operations.
(iii) The Developer shall obtain the required approval from various
statutory authorities under relevant statutes and regulations of the
Government of India and the State Government and local bodies.
(iv) The Developer shall make adequate provision for rehabilitation of the
displaced persons.
(v) The project shall be implemented and operated in terms of the Special
Economic Xxxxx Xxx, 0000 and the rules and orders made there-under.
(vi) The Developer shall conform to the environmental requirements.
(vii) The Developer shall abide by the local laws, rules, regulations or
bye-laws in regard to area planning, sewerage disposal, pollution
control, labour laws and the like as may be locally applicable.
(viii) The Developer shall raise the required funds for the project.
External commercial borrowing, if any, will be as per the guidelines
of the Ministry of Finance, Department of Economic Affairs, Government
of India, New Delhi.
(ix) This approval is valid for a period of three years within which time
the Developer shall implement the project. The project implementation
progress report will be submitted to Government of India every six
months.
(x) This approval is liable to be suspended in case of violation of any of
the terms and conditions stipulated herein.
(xi) The operation and maintenance of the facilities will be made as per
the standards specified in the proposal and to the satisfaction of the
users.
(xii) The Developer shall maintain adequate manpower to provide the
facilities.
(xiii) The user charges will be finalized in consultation with the
Development Commissioner and the users. This shall be subject to
revision as per the agreed terms.
(xiv) The Developer shall obtain the approval of Board for specific
activities proposed to be undertaken for development, operation and
maintenance of Special Economic Zone. Based on the activities approved
by the Board, the Developer shall be entitled for duty free import or
domestic procurement of goods for the approved activities under rules
10 after the Special Economic Zone has been notified.
(xv) The authorized operations shall be carried out in terms of the
parameters laid down in the Special Economic Xxxxx Xxx, 0000 and the
Rules and orders made there-under and in accordance with the proposal
approved herein.
(xvi) No duty free goods shall be available for personal use of, or
consumption by officials, workers, staff or owners of the Unit or
Developer.
(xvii) Normally, no extension of validity period of three years for
implementation of the project will be considered. Any request,
however, may be considered by the Board, on merits. Such request shall
be submitted to the Government six months before expiry of the
approval period.
(xviii) The developer shall construct a minimum built up processing area of
One Lakh square meters.
2. This approval shall be also subject to other conditions as approved by the
Board.
3. The Developer may convey acceptance of all the terms and conditions indicated
above within thirty days from the date of issue of this letter. All future
correspondence may be addressed to the Director (SEZ), Department of Commerce,
Udyog Bhavan, New Delhi-11.
4. The Developer may send exact details of the area along with a map indicating
the Special Economic Zone area certified by the District Revenue Authorities for
notification in the Gazette of India.
5. The Developer shall furnish to the Development Commissioner. Visakhapatnam
Special Economic Zone returns on import, procurement and utilization of goods,
as provided for under the Special Economic Zone Rules, 2006.
Yours faithfully,
/s/ Xxxxxxxx Xxxx
----------------------------------------
16.6.06
(XXXXXXXX XXXX)
Director
Tel. (000) 0000 0000
Email: x.xxxx@xxx.xx
Copy to:
1. Central Board of Excise and Customs (Shri A.P. Sudhir, Member
(Customs), Xxxxxxxxxx xx Xxxxxxx, Xxxxx Xxxxx, Xxx Xxxxx.
2. Central Board of Direct Taxes (Shri Xxxxxx Xxxx, Joint Secretary
(TPL-II)), Department of Revenue, North Block, New Delhi.
3. Ministry of Finance (Shri Xxxxxx Xxxxx, Joint Secretary), Banking
Division, Department of Economic Affairs.
4. Department of Industrial Policy and Promotion (Shri Xxxxx Xxxxx, Joint
Secretary).
5. Ministry of Science and Technology (Shri X.X.Xxxxx, Adviser),
Technology Bhavan, Mehrauli Road, New Delhi.
6. Ministry of Small Scale Industry (Shri Xxxxxxxxx Xxxxxx, Development
Commissioner), Xxxxxx Bhavan, New Delhi.
7. Ministry of Home Affairs (Shri X.X. Xxxxx, Joint Secretary), North
Block, New Delhi
8. Ministry of Defence (Shri Xxxxx Xxxxx, Joint Secretary (Coordination).
9. Ministry of Environment and Forests (Shri X. Xxxxxxxxxxxx, Joint
Secretary), Xxxxxxxxxxx Xxxxxx, XXX Xxxxxxx, Xxx Xxxxx - 3.
10. Legislative Department (Xx. X.X Xxxxxx, Joint Secretary and
Legislative Counsel).
11. Ministry of Overseas Indian Affairs (Shri X. Xxxxxxxxxx, Joint
Secretary (FS), Akbar Bhawan, Chankyapuri, Now Delhi.
12. Department of Urban Affairs, Town Country Planning Organisation, (Shri
K.T. Gurumukhi, Chief Planner), Vikas Bhavan (E-Block), LP. Estate,
New Delhi.
13. Director General of Foreign Trade (Shri X.X. Xxxxxx, DG), Department
of Commerce, Udyog Bhavan, New Delhi.
14. Development Commissioner, Visakhpatnam Special Economic Zone,
Visakhapatnam.
15. Govt. of Andhra Pradesh (Smt K. Xxxxx Xxxxxx, Secretary, Information
Technology and Communication), 'D' Block, Room No. 431-A, A.P.
Secretariat, Hyderabad - 500022
Copy for information to: PPS to SS (GKP)/ PPS to JS (JD)/DS (RGS).
APPENDIX B
(PROPOSED LAY OUT PLAN OF I.T. PARK AT NANAKRAMGUDA)
WITNESS
1)
2)
(SEAL)
SECTOR-A
SITE PLAN OF PLOT NO. 10, IN SY.NO.115/P ON I.T. PARK, SITUATED AT
NANAKRAMGUDA(V) R.R. DIST. A.P. ALLOTTED TO M/s. VIRTUSA (INDIA) PVT. LTD.
AREAS:- REF:-
PLOT AREA: 25,577.04 SQ.MTS./ INDLUDED: ______________________________
Ac. 6.32
BOUNDARIES:-
NORTH: PROP. 4-5.0M WIDE CDA M-P. ROAD
SOUTH: XXXX XX.0
EAST: PROP. 18.0M WIDE ROAD
WEST: PRIVATE LANDS.
(PROPOSED LAY OUT PLAN OF I.T. PARK AT NANAKRAMGUDA)
WITNESS:-
1)
2)
(SEAL)
PHOTOGRAPHS AND FINGERPRINTS AS PER SECTION 32A OF REGISTRATION ACT, 1908
FINGER PRINT IN NAME & PERMANENT POSTAL
BLACKINKLEFT PASSPORT SIZE ADDRESS OF PRESENTANT /
THUMB PHOTOGRAPH OWNER /DEVELOPER
--------------- ------------- --------------------------------------------
(OVAL) (BOX) LESSOR
l. APIIC LIMITED 0XX XXXXX XXXXXXXXX XXXXXX,
XXXXXXXXXXX,
XXXXXXXXX - 500 004.
REP. BY, PROJECT MANAGER (IPU)
SRI D. XXXXXXXXXXXXX XXX
S/O X.XX. B. XXXXXX XXX
(OVAL) (BOX) LESSEE
2. M/s. Virtusa (India) Private Limited,
3rd Floor, MyHome Tycoon, Begumpet,
Hyderabad - 500 016.
XXX.XX: FINANCIAL CONTROLLER
SRI M. HARI RAJU,
S/O M. XXXX XXXX
(OVAL) (BOX) SPL.POWER OF ATTORNEY TO (1)
SPA NO. 93/2003, DT. 27.6.2003
3. SRI C. XXXX XXXXXXXXXXXX
S/O XXXXXXX XXXXXXXX
Manager (Development),
APIIC,, Basheerbagh
Hyderabad - 500 004
SIGNATURE OF WITNESSES
1
2
