EXHIBIT 10.14
Note: Redacted portions have been marked with (***). The redacted portions are
subject to a request for confidential treatment that has been filed with the
Securities and Exchange Commission.
Procurement Agreement
between
Qwest Communications Corporation
and
Tellium, Inc.
TABLE OF CONTENTS
-ii-
AGREEMENT
This procurement agreement is made and entered into by and between Tellium
("Supplier"), a Delaware corporation, with a place of business at 0 Xxxxxxxx
Xxxxx, Xxxxxxxxx, XX 00000, and Qwest Communications Corporation, a Delaware
corporation, having its principal offices and place of business at 000
Xxxxxxxxxxx Xxxxxx, Xxxxx 0000, Xxxxxx, Xxxxxxxx 00000 ("Qwest") (Supplier and
-----
Qwest each being referred to herein as a "Party" and collectively as the
-----
"Parties").
-------
NOW, THEREFORE, in consideration of the foregoing and of the mutual
promises and covenants hereinafter expressed, the Parties hereto agree as
follows:
1. DEFINITIONS
1.1 The terms used in this Agreement shall have their normal or common
meaning, except that in addition to terms defined at other places in
this Agreement, the following terms shall have the following meanings
for the purposes of this Agreement, the Schedules and any attachments
thereto:
(a) "Affiliate" means (i) any individual, corporation, partnership,
---------
joint venture, limited liability company, limited liability
partnership, practice, association, joint stock company, trust,
unincorporated organization or other venture or business vehicle
(each an "Entity") in which a Party owns a (***) or greater
------
equity interest; (ii) any Entity which, directly or indirectly,
is in control of, is controlled by or is under common control
with a Party, as applicable, after applying the attribution rules
of Section 318 of the Internal Revenue Code; or (iii) any other
Entity agreed by the Parties. For the purposes of this
Agreement, control of an Entity ("Control") shall include the
-------
power, directly or indirectly, whether or not exercised (i) to
vote (***) (or such lesser percentage as is the maximum allowed
to be owned by a foreign corporation in a particular
jurisdiction) or more of the securities or other interests having
ordinary voting power for the election of directors or other
managing authority of such Entity; or (ii) to direct or cause the
direction of the management or policies of such Entity, whether
through ownership of voting securities, partnership interest or
equity, by contract or otherwise. Within forty-five (45) days of
the Effective Date, the Parties will amend this Agreement by the
addition of Schedule A (Approved Affiliates) containing the names
of Qwest Affiliates who have been designated by Qwest and who
have met the credit standards referenced in Section 2.4 (the
"Approved Affiliates").
-1-
(b) "Agreement" means this agreement including the schedules
---------
described in Section 2.5 and attached hereto (the "Schedules").
---------
(c) "Class A Change" means a modification, revision, replacement,
--------------
correction or release of existing Supplier manufactured Product
(other than an ISU or an Enhancement) to remedy a nonconformance
to the Specifications required to correct design defects of a
type that results in electrical or mechanical inoperative
conditions or unsatisfactory operating conditions, or which is
recommended to enhance safety, provided that the Product
incorporating such change, is at least as equally compatible with
Qwest's network components and other Supplier Products as the
same Product prior to incorporation of such change.
(d) "Current Release" means the latest Version or Release of the
---------------
Software which has been approved by Supplier for commercial use.
(e) "Days" or "days" means calendar days, unless otherwise provided
---- -----
herein.
(f) "Documentation" means the user, technical and operating manuals,
-------------
including the operating instructions, guides and manuals,
necessary to enable Qwest properly to use and maintain the
Products.
(g) "Effective Date" means September 1, 2000.
--------------
(h) "Equipment" means hardware, equipment, embedded software
---------
(including, without limitation, firmware) and all physical
components, including cabling, required by this Agreement to be
provided by Supplier.
(i) "Enhancement" means any modification or revision to the Software
-----------
that Qwest may license at its option when offered by the Supplier
in the future and which (i) substantially improves existing
functions or features, including functions and features for which
Qwest has already been granted a license, or (ii) adds new
functions or features.
(j) "Form, Fit or Function" shall have the following meaning. "Form"
---------------------
means shape; "Fit" means physical size or mounting arrangement
(e.g., electrical or mechanical connections); and "Function"
means features and capabilities.
(k) "Incremental Software Update" or "ISU" means any modification
--------------------------- ---
-2-
or revision to the Software, other than Enhancements, that (i)
corrects Software Nonconformities or other errors; (ii) supports
new releases of third party operating systems with which the
Software is designed to operate; (iii) supports new Equipment;,
(iv) improves the performance of the Software; or (v) provides
other updates and corrections. If a modification or revision
described in clause (ii), (iii) or (iv) above adds new functions
or features or substantially improves the network performance, it
shall be deemed to be an Enhancement with respect to those new
functions and features.
(l) "Installation Site" means the building, complex of buildings or
-----------------
remote site at which any of the Products are installed.
(m) "Intellectual Property Rights" mean all forms of intellectual
----------------------------
property rights and protections including, without limitation:
(i) All right, title and interest in and to all letters patent
and all filed, pending or potential applications for
letters patent, including any reissue, reexamination,
division, continuation or continuation-in-part applications
throughout the world now or hereafter filed;
(ii) All right, title and interest in and to all trade secrets,
and all trade secret rights and equivalent rights arising
under the common law, state law, federal law and laws of
foreign countries;
(iii) All right, title and interest in and to all mask works,
copyrights, other literary property or author's rights,
whether or not protected by copyright or as a mask work,
arising under common law, state law, federal law and laws
of foreign countries; and
(iv) All right, title and interest in and to all proprietary
indicia, trademarks, trade names, service marks, symbols,
trade dress, logos and/or brand names protected under
common law, state law, federal law and laws of foreign
countries.
(n) "Network Compatible" or "Network Compatibility" with respect to a
------------------ ---------------------
Product means that (i) the Product will comply with the
applicable American National Standards Institute ("ANSI") and
----
International Standards Organization ("ISO") standards in effect
---
on the date that Qwest issues the Purchase Order, and any other
-3-
standards agreed by the Parties in writing; (ii) the Product can
be operationally deployed in Qwest's network without requiring
the replacement of any Supplier equipment; and (iii) the Product
will be fully compatible and will inter-operate with other
Supplier Products provided under this Agreement. Qwest in its
sole discretion may waive the foregoing compatibility
requirements for the purpose of deploying new technology offered
by Supplier during the Term.
(o) "Nonconformity" means an instance of failure of a Product to be
-------------
Operative.
(p) "Supplier Personnel" mean any employees, trainers, or other
------------------
support personnel provided by Supplier under this Agreement
whether or not employed by Supplier (to the extent that such are
permitted elsewhere under this Agreement). Supplier shall be
performing under this Agreement at all times as an independent
contractor to Qwest, and the Supplier Personnel shall not be
considered as employees or agents of Qwest.
(q) "Object Code" means machine-readable computer instructions that
-----------
can be executed by a computer.
(r) "Operating Platform" means the computer equipment, hardware and
------------------
operating system, which execute the Object Code and on which the
Software runs.
(s) "Operative" means (i) conforming in all respects to the
---------
Specifications, the requirements of this Agreement and the
applicable Purchase Orders in effect at the time Supplier accepts
the Purchase Order, and (ii) Network Compatible.
(t) "Products" mean the Equipment, Software, and Documentation,
--------
including any part thereof, described in the Schedules, which
this Agreement requires Supplier to furnish or that Supplier
furnishes hereunder. Qwest and Supplier may amend the Schedules
by written agreement to include other products offered for sale
by Supplier.
(u) "Program Manager" means the senior manager of a Party who shall
---------------
have overall responsibility for the day-to-day management and
administration of this Agreement and who shall work together with
the other Party's Program Manager to facilitate an efficient
delivery of Products and Services.
-4-
(v) "Purchase Order" means the written instrument described in
--------------
Section 7, a form of which is attached hereto as Schedule B,
----------
under which Qwest orders and Supplier delivers Products or
Services under this Agreement.
(w) "Release" means any revision, modification, replacement, or
-------
correction to the Software, including an Enhancement or ISU, that
Supplier makes available to any of its customers for use.
(x) "Representative" means, with respect to a Party, employees,
--------------
officers, agents or advisors of such Party.
(y) "Segment" means a continuous route within the Qwest network.
-------
(z) "Services" mean work performed and labor provided by Supplier,
--------
including, but not limited to, design, engineering and
implementation of Products, Software testing, warranty, technical
support, training and similar activities.
(aa) "Software" means any software, including Object Code and Source
--------
Code that is delivered to Qwest under this Agreement, inclusive
of the Supplier Intellectual Property Rights, whether or not the
subject of any patent or copyright, issued or pending. Software
may include programs used to create, enhance, test or maintain
any Product delivered under this Agreement. Software includes
all Releases and Versions.
(bb) "Source Code" means the human-readable code from which a computer
-----------
can compile or assemble the Object Code of the Software, together
with a description of the procedure for generating the Object
Code.
(cc) "Specifications" mean the functional, performance, design,
--------------
operational, and physical characteristics of a Product or System,
as described in the applicable ANSI and ISO standards and
Supplier proposal. If an ANSI or ISO standard is not available
for a new Product, the formal specification developed by Supplier
and provided to Qwest shall be used.
(dd) "System" means an Operative combination of Products designed,
------
engineered, furnished, installed or implemented by Supplier under
this Agreement.
(ee) "Turn-Over" means, with respect to a delivered Product, the
---------
acceptance procedure set forth in Section 12 has been completed.
-5-
(ff) "Version" means a Release of Software intended for use with a
-------
particular make and model of computer or a particular operating
system.
(gg) "Warranty Period" means the time period specified in Section 17.
---------------
1.2 Additional definitions appear elsewhere in the recitals and subsequent
Sections of this Agreement.
2. SCOPE
2.1 The initial term of this Agreement ("Initial Term") commences on the
------------
Effective Date and continues until December 31, 2003 unless earlier
terminated or extended in accordance with other provisions of this
Agreement or unless extended in writing by the Parties.. At its
option, Qwest may extend the Initial Term for a period of up to six
(6) months (the "Extended Term") by written notice to Supplier prior
to the expiration date of this Agreement (the Extended Term, if any,
together with the Initial Term, are hereinafter the "Term").
2.2 (a) Subject to the terms and conditions of this Agreement, including
its Schedules, during the Initial Term, Qwest will make purchases of
Products under this Agreement as follows: (a) during the period from
the (***) until (***) Qwest will make purchases under this Agreement
in an aggregate amount of not less than (***) (the "First Milestone"),
(b) during the period from January 1, 2002 until December 31, 2002,
Qwest will make purchases under this Agreement in an aggregate amount
of not less than (***) (the "Second Milestone") and (c) during the
period from (***) until (***), Qwest will make purchases under this
Agreement in an aggregate amount of not less than (***) ( the "Third
Milestone," and together with First Milestone and Second Milestone,
the "Commitment"). The above amounts are net of any discounts Qwest
receives on the price of the Products.
(b) Supplier will complete development and deployment of the products
and deliverables as set forth in the attached Schedule J. If Supplier
(a) fails to meet any purchase order delivery date due to a delay or
failure to have the products described in Schedule J available for
successful general availability as of their corresponding delivery
dates, or (b) otherwise fails to have the products described in
Schedule J available for successful general availability as of their
corresponding delivery dates, the Parties agree to negotiate in good
faith and make appropriate amendments to the Initial Term, the outside
dates of the Milestones or an appropriate reduction in the Commitment.
If such negotiations do not result in
-6-
mutually acceptable resolution, either party may terminate this
Agreement for cause following completion of the dispute resolution
process as set forth in Section 25. When used in this Section 2.2(b)
and in Schedule J, "available for successful general availability"
shall mean that such products have successfully completed tests (***)
to the (***), in which Qwest shall be entitled to participate, and are
available for general availability on Tellium's general price list.
(c) Subject to Section 21.3, all purchases of Products or Services
from Supplier and its Affiliates by Qwest and Qwest Affiliates will be
credited toward the Commitment. Any purchases made in excess of the
First Milestone amount will be credited towards the Second and Third
Milestone amounts. Any purchases in excess of Second Milestone amount
will be credited towards the Third Milestone amount.
2.3 This Agreement shall apply to the transactions in which Supplier
furnishes the Products or Services described in the Schedules to Qwest
during the Term.
2.4 Approved Affiliates may issue a Purchase Orders under this Agreement.
Affiliates who are not Approved Affiliates may become Approved
Affiliates if they (i) (***), which fulfillment of (***) will
determine within (***) after notice from (***) and (ii) (***) and
(***) of this Agreement. If Supplier has not provided written
acknowledgement of an Affiliate's failure to meet such credit
standards within such (***) period, the Affiliate shall be deemed to
have been authorized to purchase under this Agreement and shall be
deemed an Approved Affiliate. If there has been a transfer of (***)
or more of the assets of any Approved Affiliate who (i) is seeking to
place an new Purchase Order under this Agreement or (ii) has an
outstanding Purchase Order of (***) or more, Supplier shall have the
right to (***) Purchase Order and the right to review such Approved
Affiliate's (***) as such. If, upon review, the Approved Affiliate no
longer qualifies for approval pursuant to this Section, Supplier shall
have the right to (***), and it shall (***) to place Purchase Orders
under this Agreement without the satisfaction of another (***).
2.5 The following Schedules attached hereto are an integral part of this
Agreement and are incorporated herein by reference.
A. Approved Affiliates
B. Form Purchase Order
C. Product Price List
D. Purchase Order Confirmation Procedure
E. Training
F. (***)
G. Technical Support Services
-7-
H. Tellium Repair and Return Policy
I. Software Maintenance Agreement
J. (***)
3. SUPPLIER OBLIGATIONS
3.1 Supplier shall perform all Services and deliver all Products necessary
to fulfill the requirements of this Agreement and shall perform all
work in a professional and workmanlike manner, in accordance with all
requirements, acceptance criteria and Specifications of this Agreement
and the warranties provided hereunder. Among its obligations,
Supplier shall:
(a) complete all tasks required by an accepted Purchase Order by
providing all necessary resources, personnel, materials and
equipment;
(b) adhere to agreed delivery dates;
(c) supervise and manage the overall Supplier effort under each
Purchase Order and this Agreement and coordinate its efforts with
the Qwest Program Manager; and
(d) provide competent personnel of sufficient experience and
expertise to fulfill the goals of this Agreement.
3.2 In addition to other requirements contained in this Agreement,
Supplier will consider the following Qwest objectives in its delivery
of Products and Services under this Agreement:
(a) ensuring a smooth transition from the existing products to new
Products provided hereunder as possible;
(b) training; and
(c) using an orderly approach for any significant implementation of
new Products.
3.3 Supplier is responsible for providing qualified personnel in the
quantities and of the experience necessary to fulfill the requirements
of this Agreement. When requested by Qwest, Supplier shall provide the
names of Supplier Personnel providing Services at Qwest sites.
4. QWEST OBLIGATIONS
-8-
4.1 By the end of the third quarter of each calendar year, Qwest will
provide Supplier with a forecast of Qwest's estimated Product
requirements for the next calendar year (each a "Forecast"). Qwest
will update this Forecast each quarter and when significant changes
occur. The Forecast shall be for planning purposes only and shall not
represent Qwest's commitment to purchase any or all such Products or
create any other obligation whatsoever by Qwest.
4.2 Qwest agrees that all Supplier Personnel who are approved in writing
by Qwest to be involved in any effort under this Agreement will be
provided reasonable access to Qwest's premises during mutually agreed
times as necessary. Supplier Personnel shall comply with site and
security regulations specified by Qwest.
4.3 For all Products not on Supplier's price list ("Non-Price List
Products"), Qwest shall issue a written request for proposal ("RFP")
to Supplier no later than (***) prior to the required equipment ship
date for Non-Price List Products included in the Forecast. Non-
forecasted Non-Price List Products equipment will require (***)
advance notice to Supplier. Supplier's sales engineering shall issue
a written proposal to Qwest for Product purchases within two weeks of
receipt of the RFP, or a reasonable time thereafter as necessary to
complete the proposal.
5. GOVERNANCE
5.1 Meetings.
--------
By October, 1, 2000, the Parties will mutually determine appropriate
intervals for periodic meetings to be held between representatives of Qwest
and Supplier. At a minimum, these meetings will include the following:
(a) a weekly meeting between the respective project management teams;
(b) a monthly management meeting to review Supplier's progress under
open Purchase Orders, project schedules, financial and
administrative matters and such other matters as appropriate; and
(c) a quarterly executive review meeting to review relevant contract
and performance issues.
Each Party's Program Manager or individual designated by the Program
Manager will attend each meeting.
-9-
5.2 Personnel.
---------
Qwest reserves the right to require replacement of any Supplier's employee
or contractor performing work for Supplier under this Agreement if Qwest is
dissatisfied with the performance of that individual and determines that
the continued assignment of such individual is not in the best interest of
Qwest. Qwest shall give Supplier written notice requesting that the
individual be replaced (***). Supplier shall replace such individual with
a person of suitable ability and qualifications within (***) from the
request or such additional time period as may be reasonably required under
the circumstances.
5.3 Reports.
-------
Supplier shall provide to Qwest written progress reports as agreed by the
Parties, on at least a weekly basis, delivered by electronic mail followed
by a paper copy to Qwest's designated representative. Progress reports
shall include: (i) the status of delivery under all open Purchase Orders
for Products; (ii) items completed during the reporting period; (iii) items
to be completed within the next reporting period; (iv) open action items;
and (v) any other action items required by Qwest, listing the party
responsible for such actions.
6. PRICING
6.1 Qwest will receive incremental discounts off the list price of the
Products set forth in Schedule C (the "List Price") based upon its
aggregate purchases of Products under this Agreement (the "Aggregate
Purchase Amount") as follows:
(a) When the Aggregate Purchase Amount is less than or equal to
(***), Qwest shall receive a (***) discount off List Price for
such increment; and
(b) When the Aggregate Purchase Amount is greater than (***) but less
than or equal to (***), Qwest shall receive a (***) discount off
List Price for such increment; and
(c) When the Aggregate Purchase Amount is greater than (***) but less
than or equal to (***), Qwest shall receive a (***) discount off
List Price for such increment; and
(d) When the Aggregate Purchase Amount is greater than (***) but less
than or equal to (***), Qwest shall receive a (***) discount off
List Price for such increment; and
-10-
(e) When the Aggregate Purchase Amount is greater than (***) but less
than or equal to (***), Qwest shall receive a (***) discount off
List Price for such increment; and
(f) When the Aggregate Purchase Amount is greater than (***), Qwest
shall receive a (***) discount off List Price for such increment.
All above amounts are net of Qwest's discount.
An illustration of how such discount structure works is as follows.
For purchases up to (***), Qwest shall receive a (***) discount on the
(***) of Product and a (***) discount on the additional (***) of Product.
Total net Product purchased would be (***).
7. ORDERING
7.1 (a) Qwest (or an Approved Affiliate) shall issue Purchase Orders, a
form of which is attached hereto as Schedule B, to acquire all
-----------
Products and Services under this Agreement. All Purchase Orders must
be submitted (***) prior to the delivery date designated in the
Purchase Order (with respect to (i), below) or as agreed upon by the
Parties (with respect to (ii), below) (the "Order By Date"). Upon
request by Qwest, the Parties will in good faith discuss a shorter
period for Purchase Order submission.
(i) For all Purchase Orders less than or equal to (***) of the
Forecast amount which are submitted prior to the Order By Date,
Supplier agrees to be bound by the designated delivery date.
(ii) For all Purchase Orders that are in excess of (***) of the
Forecast or are submitted after the Order By Date, (***) will (***) on
the (***).
7.2 Supplier shall confirm and accept the Purchase Order in writing in
accordance with Schedule D at which point the Purchase Order shall
----------
become a binding commitment. Subject to Section 7.1, Supplier agrees
to accept all Purchase Orders issued by Qwest under this Agreement
provided that such Purchase Orders conform with the requirements of
this Agreement.
7.3 Any changes to a Purchase Order shall be made in writing.
7.4 All Purchase Orders issued hereunder by Qwest or the Approved
Affiliates shall reference this Agreement and shall be deemed to
incorporate and be governed solely by the terms and conditions set
forth herein. Any changes to the terms and conditions of the
Agreement contained in any Purchase
-11-
Order or Supplier's written acknowledgement thereof shall have no
force or effect.
7.4 Approved Affiliates may purchase Products and Services under this
Agreement, provided that the Approved Affiliates agree to be bound by
the applicable terms and conditions of this Agreement.
8. DELIVERY AND SHIPMENT
8.1 Supplier shall deliver Products as required under this Agreement to
Qwest or Approved Affiliates (as applicable) at the locations and at
the times specified by Qwest or Approved Affiliates (as applicable),
and agreed to by Supplier in an accepted Purchase Order, this
Agreement or as otherwise agreed in writing by the Parties. For
purposes of this Section 8, "Buyer" shall mean Qwest or its Approved
Affiliate, as applicable. Supplier shall deliver all Products and
Services at the designated location in a timely manner.
8.2 Supplier shall ship all Products, freight prepaid, FOB destination
designated in the Purchase Order or to such other location as the
Parties may agree ("Destination"). The method of shipment shall be
-----------
consistent with the nature of the Products and hazards of
transportation. Risk of loss for all Products ordered in accordance
with this Agreement shall pass to Buyer upon delivery by Supplier at
the Destination except loss or damage attributable to the Supplier's
fault or gross negligence. Such loss, damage, or destruction shall
not release Supplier from any obligation hereunder. Title to Products
(excluding Software) shall pass to Buyer upon delivery to the
Destination. Supplier shall convey good title, free from any claim or
encumbrance, for all Products (excluding Software) delivered to Buyer
under this Agreement. Supplier will pack the Products purchased
hereunder for transport in accordance with its commercial standards
and will deliver the Products to a carrier of the mode of
transportation selected by Supplier unless otherwise agreed upon in
writing by the Parties.
8.3 If Supplier fails to meet any agreed schedule, Buyer, without limiting
its other rights or remedies as may exist, may direct expedited
routing of Products and any excess costs incurred thereby shall be
paid by Supplier unless otherwise agreed in writing by the Parties.
Buyer shall not be liable for Supplier's commitments or production
arrangements in excess of the amount, or in advance of the time,
necessary to meet Buyer's delivery schedule. Delivery shall not occur
(***) in advance of the scheduled date of delivery unless otherwise
agreed in a signed writing by Supplier and Buyer. For delivery to new
sites, such advance delivery shall not be
-12-
allowed, except as set forth in a signed writing executed by Buyer. If
delivery occurs prior to the period authorized above and designated
storage has not already been established by Supplier, Buyer may (i)
return delivered items at Supplier's expense for proper delivery, or
(ii) place delivered items in storage at Supplier's expense until the
scheduled date of delivery.
8.4 The Parties agree that for all shipments that otherwise meet the
designated delivery dates (a) any failure to supply all Products
ordered in a single shipment or (b) any partial shipment or delivery
of an Order in installments shall not constitute a breach of this
Agreement provided that Supplier has received Buyer's prior written
approval of the same, such approval not to be unreasonably withheld.
8.5 Performance Incentives
(a) Subject to Section 8.4, for accepted Purchase Orders of Products
with an aggregate value of (***) or more, Supplier and Qwest
agree that it may be difficult, if not impossible, to accurately
determine the amount of damages that Qwest may incur if Supplier
fails to deliver the Products as scheduled. Accordingly, if
delivery has not occurred with respect to any Product, Segment or
System (***) of a Forecast as of the scheduled date, in addition
to its other rights and remedies hereunder, Buyer shall be
entitled to daily performance incentives in a specified and
predetermined amount of (***) of the total price of the affected
Product, Segment or System, per day late, up to a maximum of
(***) of total price of the Product, Segment or System
("Performance Incentive").
-----------------------
(b) Buyer shall not assess Performance Incentives to the extent that
Supplier has been delayed by Buyer not fulfilling its obligations
described in Section 4.
(c) Buyer may in its sole discretion by written notice to Supplier
(a) unilaterally delay the scheduled delivery date of any Product
or Service or (b) cancel or suspend delivery of any Product or
Service ordered under this Agreement. Such unilateral delay,
cancellation or suspension shall be without penalty or cost
provided that Buyer gives written notice to Supplier at least
(***) prior to the scheduled shipping date of the affected
Product or the scheduled delivery date of the affected Service.
If a delay directed by Buyer lasts more than (***) beyond the
scheduled delivery date of the Product, or a cancellation
directed by Buyer occurs within (***) of the scheduled shipping
date of the Product, Buyer agrees to pay
-13-
Supplier for the actual restocking costs it incurs as a result of
the delay or cancellation, not (***) of the (***) of the affected
Product. The foregoing shall be Supplier's sole remedy for delay,
cancellation or suspension of the delivery of a Product or
Service by Buyer.
8.6 Equipment Tracking Data. Supplier shall provide Qwest with quarterly
reports containing the following information in a jointly developed
format. The reports shall contain Equipment information, including:
(1) a description of the Equipment; (2) Supplier part number; (3)
Equipment destination by building (final); (4) shipping date; and (5)
Supplier serial number.
8.7 In the event that Qwest installs a bar coding system for its fixed
assets, Supplier shall apply a Qwest asset tag (to be supplied by
Qwest) at either the manufacturing site or at the point of shipment
for the Equipment in a manner that allows Qwest to easily read the
asset tag. Supplier may charge an agreed fee to cover any reasonable
Supplier's costs associated with such bar coding system. A joint
meeting will be held between Supplier and Qwest within thirty (30)
days of contract execution to further define these requirements and
fees (if any).
9. PAYMENT TERMS
9.1 Subject to Section 12, Supplier shall invoice Qwest for Products upon
shipment (and shall invoice Approved Affiliates for shipment to
Approved Affiliates) and Qwest (or the Approved Affiliates) shall pay
to Supplier the price of each shipment (including any prepaid
transportation and/or insurance) within (***) from the date of
Acceptance. For all other Services (including Services provided to any
Approved Affiliate), Supplier shall invoice Qwest (or the Approved
Affiliate, as applicable) upon Acceptance of the Services. Charges
for any other amounts payable pursuant to this Agreement shall be paid
by Qwest within (***) from the date of invoice. All payments shall be
made in U.S. Dollars. The date of the payment shall be deemed to be
the date (***) is (***).
9.2 Qwest is not required to pay invoiced amounts disputed in good faith
until such dispute is resolved; provided, however, Qwest shall pay
that (***) of a (***) which is (***) unless it is (***) to (***).
Once the dispute is resolved, the invoice shall be paid within (***)
following such resolution, or in the time frame set out in Section
9.1, whichever is greater.
-14-
9.4 Credits owed to Qwest under this Agreement, may be applied against
amounts owed to Supplier under this Agreement, or at Qwest's request
for amounts other than Management Discounts, retroactive discounts
paid to Qwest within (***) following such request.
9.5 Payment shall not be considered Acceptance of any Products or Services
(which Acceptance shall be as set forth in Section (12). Supplier
shall provide Equipment, Software and Services without interruption in
the event of disputes concerning an invoice amount provided that the
Parties are working together in good faith to resolve the dispute.
10. PRODUCT REQUIREMENTS
The following provision shall apply to all Products provided under this
Agreement.
10.1 Documentation.
-------------
(a) Supplier shall furnish to Qwest one set of Documentation per
Installation Site on CD ROM, and a reasonable number of complete
sets in both CD ROM and paper form for Qwest engineering staff
for use in the operation and ongoing maintenance of the Products.
Supplier shall deliver reasonable Documentation to allow Qwest to
install and use each ISU and Enhancement.
(b) Qwest may copy the Documentation subject to the rights and
restrictions in this Agreement and for Qwest's internal use only.
All such Documentation is to be treated in accordance with the
terms of this Agreement. Updates to Documentation shall be
provided at no charge during the Warranty Period.
(c) The Documentation shall describe fully the proper procedure for
using the Products and provide sufficient information to enable
Qwest to operate and maintain the Products.
10.2 Equipment.
---------
(a) Supplier shall make available to Qwest sufficient repair and
spare parts for each Product furnished under this Agreement to
keep such Product Operative for a period of (***) from the date
of last shipment of the Product. (***) for (***) shall not
exceed (***) for (***) from the (***) of (***). After such
period, the (***) for such (***) shall be at (***). Supplier, at
its option and expense, may replace Products for which repair
parts are no longer available
-15-
with functionally equivalent Products provided that such products
are Network Compatible.
(b) Supplier shall provide Qwest with written notice of the
manufacturing discontinuance for any particular Product, and,
subject to subsection (a) above, shall furnish the repair parts
to Qwest at the (***) unless furnished during the Warranty Period
in which case a supply that may be reasonably needed during the
Warranty Period, and would otherwise be included at no cost
pursuant to the Warranty provided in Section 17, shall be
supplied (***).
(c) Supplier shall neither provide nor incorporate any Product which
adversely affects Form, Fit or Function, Network Compatibility,
interface or interchangeability of Qwest's existing hardware or
software environment without the prior express written approval
of Qwest. Qwest shall notify Supplier if it becomes aware that a
Product is not Network Compatible.
(d) In the event of a Class A Change; Supplier shall provide
immediate written notice to Qwest and shall proceed promptly to
make the necessary changes at Supplier's expense per the repair
and return procedures set forth in Schedule H, Supplier shall
----------
bear all costs and expenses relating to such retrofit or
replacement and all peripheral equipment and software
(e) All changes must be Network Compatible.
-16-
10.3 Substitutions and Modifications.
-------------------------------
Supplier shall give Qwest (***) advance written notice of any material
modification in the design or Specifications of the Products supplied
hereunder to Products previously made available hereunder. If any
such modification, which affects the Form, Fit or Function of the
Products and (i) adversely affects the expected life, operation or
performance of any Equipment or Software; (ii) causes Qwest to incur
significant costs (including without limitation a write down of
equipment or equipment-related assets); (iii) prevents proper
operation of equipment in the Qwest network that otherwise meets
Specifications; or (iv) prevents any Product from meeting the
applicable Specifications, Qwest shall have the right to return to
Supplier such modified Product and Supplier shall have the obligation
of replacing such modified Product with compliant Product. No such
replacement or substitution shall result in an increased purchase
price.
10.4 Incremental Software Updates.
----------------------------
During the Warranty Period and in accordance with Section 13.2,
Supplier shall offer to Qwest any ISUs contained in a Release or
Version of the Software at no additional charge when they are made
available to any of Supplier's other customers or upon a production of
new Release or Version. Providing such ISUs shall not relieve Qwest
of its obligation to pay license fees otherwise due for Enhancements
used by Qwest. Qwest shall be responsible for installation of such
ISUs in the network. Supplier shall make all Releases available to
Qwest no later than it makes the same available to any of Supplier's
other customers.
10.5 Training.
--------
Supplier shall provide the training courses referred to in Schedule E
----------
at the prices set forth in Schedule C. Supplier shall provide, at no
----------
additional charge, (***) network training seat days ("Seat Days") for
---------
the Term of this Agreement; provided, however, that (***) where the
training involves teaching trainers how to train other individuals at
Qwest (hereinafter a "Train The Trainer Seat Day") will count as
--------------------------
(***). The training will take place at a Supplier training location
agreed to by the Parties, and will consist of materials developed and
controlled by Supplier. All travel and living expenses for the
training sessions shall be borne by Qwest. Training in addition to
that described in this Section 10.5 shall be provided at the then
current Supplier rates.
-17-
11. CHANGES IN THE WORK
11.1 If Qwest finds there is a need to request that Supplier perform
services or provide products beyond the scope of this Agreement, then
(i) Qwest shall submit a proposed amendment to the Schedules or this
Agreement in writing and (ii) Supplier shall evaluate the impact of
the proposed change considering cost, schedule and performance as well
as any impact on the delivery of Products and Services to be provided
hereunder and shall respond by providing Qwest with a formal proposal.
The Parties may then further negotiate the proposed amendment or
incorporate Supplier's proposal by written agreement as an amendment
to this Agreement.
11.2 If Supplier finds that there is a need for it to perform services or
provide products beyond the scope of this Agreement, then Supplier
shall submit a formal proposal detailing the proposed amendment in
writing and evaluating the impact of the proposed amendment on cost,
schedule and performance as well as any on the delivery of Products
and Services to be provided hereunder. The Parties may then further
negotiate the proposed amendment or incorporate Supplier's proposal by
written agreement as an amendment to this Agreement.
11.3 Any additional charges authorized by Qwest in writing, not contained
in any Purchase Order or Schedule, shall reflect Supplier time and
materials (and Supplier subcontractor time and materials) as stated in
Schedule C or as otherwise agreed by the Parties in writing.
----------
11.4 Claims for Delay.
----------------
(a) If Supplier wishes to request an extension in the delivery date
for Products provided in a Purchase Order, written request shall
be given to Qwest at the time the delay begins, or within (***)
thereafter if the resulting delay was not reasonably foreseeable.
The request shall state the circumstances of the occurrence, the
justification for the delay and extension of time, and the
estimated duration of the delay and extension requested.
Supplier shall also be obligated to do all in its power to
mitigate the adverse impact of such delay at no additional cost
to Qwest.
(b) Supplier agrees that it shall not request extensions of time
resulting from normal inclement weather.
(c) An extension of time shall be the sole remedy of Supplier for any
delay caused by any reason or occurrence. Subject to Section
8.5, Supplier acknowledges such extension of time to be its sole
-18-
remedy and agrees to make no claim for damages or added charges
of any sort for delay in the performance of this Agreement or any
Purchase Order for any reason. Entitlement to any such extension
of time shall be subject to compliance with all notice and
submission requirements imposed by the Agreement concerning such
claims.
12. (***) AND ACCEPTANCE
12.1 (***).
----------------
All Products shall be subject to a (***) as set forth in (***) hereto.
In addition, for Products not certified by Qwest as (***) Accepted,
Qwest agrees to (***) and (***) a (***) by (***) by (***), such (***)
to be generally in accordance with (***), and as finally (***) by
(***). Upon successful completion of the (***) Qwest will (***) in a
form determined by Qwest, such Products as certified for "Expedited
---------
Acceptance." Upon receipt of such certification by Qwest, Qwest and
----------
the Approved Affiliates shall have the right to inspect and reject
such Products for failure to be Network Compatible or other errors for
a period of (***) from delivery (the "Expedited Inspection Period").
Such Products shall be deemed to have passed inspection and accepted
after the expiration of the Expedited Inspection Period, unless Qwest
or the Approved Affiliate notifies Supplier, during the Expedited
Inspection Period, of a reasonable cause for rejection of the Products
due to a failure (***) or other error.
For all Products that have not been (***) Accepted by Qwest, each
Approved Affiliate may perform (***). Upon successful completion of
the (***), such Approved Affiliate (***) that for such Approved
Affiliate, such Product is certified for Expedited Acceptance. Such
Approved Affiliate shall then have the right to inspect and reject
such Product for failure to be Network Compatible for the Expedited
Inspection Period.
12.2 Acceptance.
----------
For any Products not certified for Expedited Acceptance, Qwest shall
have the right to inspect and reject such Products for failure to be
Network Compatible or other errors for a period of (***) from
scheduled delivery (the "Inspection Period"). Such Products shall be
deemed to have passed inspection and accepted after the expiration of
the Inspection Period, unless Qwest notifies Supplier, during the
Inspection Period, of a
-19-
reasonable cause for rejection of the Products due to a failure to be
Network Compatible or other error. Notwithstanding the foregoing,
Products will be deemed accepted upon the full (***) for (***) with
(***) by Qwest, irrespective of Expedited Acceptance status or the
expiration of the Inspection Period. Any subsequent order of a Product
that has previously been accepted pursuant to this Section 12.2 (***)
the (***) in (***).
12.3 Failure of Acceptance.
---------------------
Qwest's payment obligations in Section 9 are contingent upon
acceptance of the corresponding Product and related Services in
accordance with Sections 12.1 and 12.2 and (***). If a Product
fails to achieve acceptance as provided in Sections 12.1 and 12.2,
Qwest may return the Product, title to which shall pass to Supplier
upon delivery to Supplier, and apply amounts paid for such Product, if
any, and related Services to any unpaid Supplier invoice hereunder
upon written notice to Supplier, or upon written demand by Qwest,
Supplier shall repay such amounts, if paid by Qwest, to Qwest.
12.4 New Products.
------------
In the event Supplier develops New Products Supplier will give Qwest
(***) notice thereof, along with the expected Specifications therefor
and pricing and discounts. Qwest may request that this Agreement be
amended in order to make the terms of this Agreement applicable to the
purchase by Qwest of New Products and the Parties shall negotiate in
good faith the terms of such amendment, including pricing, discounts,
and delivery schedules, and the conduct by Qwest of a (***) for
the New Product. Such (***) shall be substantially similar to
the (***) described in (***) hereto. If the (***)
-----
for the New Product is successful, such New Products will be certified
for Expedited Acceptance and the terms of this Agreement, as amended
with respect to the New Product, shall apply to the purchase and sale
of such new Products. New Products shall mean Products with material
changes in previously applicable Specifications, which Specifications
have not been approved by Qwest.
13. SOFTWARE
13.1 License Grant.
-------------
Upon delivery of Software hereunder, Supplier grants to Qwest and its
Affiliates (***) and (***), (for the purposes of this Section, each a
-20-
"Licensee") a nonexclusive, irrevocable, perpetual, worldwide license
--------
and right to use and make copies of the Software and the Intellectual
Property Rights for which Qwest has paid Supplier a license fee for
use solely with the applicable Products so long as Licensee uses such
Products in accordance with this Agreement. Enhancements may be
provided at a later date as set forth in Schedule C. A "right to use"
license under the same terms and conditions as set forth in this
Section 13 for such Enhancement will be effective upon payment by
Qwest.
13.2 Releases.
--------
Supplier may, from time to time, issue Releases of the Software. As
set forth in Section 1 (Definitions), Supplier may classify such
Release as (i) an Enhancement, (ii) an ISU or (iii) both. During the
Warranty Period and the term of any maintenance or support agreement,
(***) shall (***) with (***) of (***). Qwest acknowledges that from
time to time Enhancements may be contained in a Release that have not
been licensed to Qwest. Qwest and Supplier shall agree in writing on
the license fee for Enhancements that Qwest, in its sole discretion,
decides to use. Notwithstanding the foregoing, ISUs and Enhancements
shall not include the cost of any associated hardware that may be
required to update such ISUs. Qwest shall be responsible for the
installation of such Releases in the Network.
13.3 Title.
-----
Subject to Section 13.5, Title to the Software described herein shall
remain with Supplier, or with the various suppliers to Supplier whose
software or software components are contained in the Software and
whose rights of ownership are maintained through restrictive
agreements with Supplier.
13.4 Limitations of License Grant.
----------------------------
(a) The Software and Documentation are to be used only by the
Licensee, for its own business use, and only for the intended use
of the Software and Documentation (***) and (***) and only in
connection with Product for which a license fee has been paid.
(b) Licensed use is limited to the Software as delivered by Supplier
to Licensee and does not permit modification or use of any
modified form of the Software, except for minor user
modifications or customizations. Licensee may not duplicate the
Software, except to make a reasonable number of backup copies of
the Software for use in the event of Product failure. If
duplication (***) for (***)
-21-
then (***) shall (***) and (***) to (***) the (***) of (***).
(c) The Software and Documentation furnished hereunder are the
property of Supplier and are to be considered Supplier's
proprietary information. Licensee shall not (***) or (***) the
(***) or (***), or (***) or (***) of (***)), before or after
termination of this Agreement, except as may be permitted in
writing by Supplier. Licensee shall immediately notify Supplier,
in writing, of any knowledge that any unlicensed party possesses
the Software or Documentation. Licensee shall safeguard said
Software with the same degree of care and diligence as Licensee
affords to its own similar property.
(d) Qwest acknowledges that Software may contain programs that have
been supplied by, and are proprietary to, third party software
suppliers. The terms and conditions of any such third party
program licenses may be different than the terms herein, and in
such event, Qwest must agree in writing to such terms prior to
delivery for such terms to be effective. Supplier will extend to
Qwest any rights Supplier may have under any such third party
licenses
13.5 Derived Products and Derived Dependent Products.
-----------------------------------------------
(a) Any (i) Qwest (or Qwest Affiliate) (***) from the (***) of the
(***) and the (***) of (***) by Qwest (ii) Qwest (or Qwest
Affiliate) (***) or (***); (iii) Qwest (or Qwest Affiliate) (***)
or (***) of the (***) or (***) Qwest; and (iv) unless otherwise
set forth in a signed writing by the Parties referencing this
Section, any portion of a (***) configuration, application or
arrangement of the Software created by Supplier (either with or
without Qwest) after a (***) by Qwest therefore shall not be
considered derived products and shall be distinct in ownership
from that of the Software as received by Qwest and shall be owned
by Qwest (and are hereby assigned to Qwest) (collectively, the
"Qwest Products"). The foregoing (iv) shall not (***) to (***) or
(***) or (***) and does not (***) in any (***) to (***) of the
(***) from (***) of any (***) or (***). Any other configuration,
application, or arrangement of the Software, shall be considered
a derivative work and shall be the sole and exclusive property of
Supplier; provided, however, that Supplier may, at its
discretion, assign or license (***) or (***) not to be
unreasonably withheld.
(b) Any (***) or (***) of (***), which are (***) of the (***) and are
-22-
(***) the (***) for (***), shall be considered a derived products
to which Supplier retains title and ownership and to which
Licensee is granted an exclusive perpetual, irrevocable,
worldwide right to use solely in its dependent form, and in
conjunction with the Software for so long as such Licensee uses
such Software in accordance with this Agreement.
(c) Supplier expressly prohibits, and Licensee agrees to refrain
from, any attempt by Licensee, Licensee's agent or to permit any
third party to disassemble, reverse compile, reverse engineer,
or, in any similar way, expose the actual instruction sequences,
internal logic, protocols, algorithms or other intellectual
property represented within the Software, which Supplier
considers to be its proprietary information and trade secret
whether or not said intellectual property is included in any
patent or copyright. Notwithstanding any other provision of this
Agreement, any (***), or (***) by Licensee or any other party
shall not be assigned and shall be deemed the property of
Supplier, for which no right to use is granted to Licensee herein
and for which Supplier shall bear no obligations for support.
13.6 Software Maintenance and Support.
--------------------------------
(a) Supplier shall provide Software technical support services as
provided in Schedule G.
----------
(b) Notice to Qwest of corrections or additions, modifications or
adjustments to the Software generally available to other
Supplier's customers with the same Release shall be sent to a
designated Qwest contact. Supplier will, at its own discretion,
make such additions, modifications or adjustments to the Release
of the Software commonly known as the Current Release except if
such adversely affects the Form, Fit or Function, in which case
Qwest may refuse to accept such without amending its rights or
Supplier's obligations hereunder.
(c) Supplier agrees that at any point in time it will support the
then Current Release of the Software plus the (***) immediately
preceding Releases.
13.7 (***) Delivery.
--------------
(a) Supplier shall keep and maintain a copy of Software (***) and
other Documentation relevant to the use and maintenance of the
-23-
Software licensed hereunder, including without limitation the
Current Release of the Software. Should Supplier at a future
date (i) declare voluntary bankruptcy or be the subject of an
involuntary bankruptcy (***) or (***) (or, (***) may (***) or
(***)) of the Software; or (ii) cease supporting the Products or
any other product incorporating such Software (***) pursuant to
this Agreement for a non-material amount of time, then Supplier
agrees and commits to Qwest that it will promptly and (***) to
the fullest extent permitted by any third party intellectual
owners, make available all such Software (***) which Supplier has
a legal right to sublicense, and hereby grants to Qwest a non-
exclusive perpetual, irrevocable, worldwide license to use,
modify (including creating derivative works), and copy such
Software (***) solely for the purpose of supporting and
maintaining the Products including Software and only for so long
as Licensee (***) such Products or Software in accordance with
this Agreement.
(b) Supplier acknowledges that if a trustee in bankruptcy or Supplier
as a debtor in possession rejects this Agreement, Qwest may elect
to retain its rights under this Subsection as provided in Section
365(n) of Xxxxx 00, Xxxxxx Xxxxxx Code (the "Bankruptcy Code").
---------------
In that event, the license for the Software (***) will include
the following provisions:
(i) Qwest has no further recourse with respect to support in
the areas to which the license applies;
(ii) Supplier will assume no obligations or liabilities with
respect to infringement (related to the (***)), and/or
Qwest's inability to successfully support the Software
(***); and
(iii) Supplier's then standard terms applicable to
confidentiality obligations and Supplier's disclaimer of
liabilities with respect to Qwest's subsequent use (of the
Software (***)).
13.8 Documentation.
-------------
In addition to the requirements of Section 10.1, Supplier shall
provide one set of instructions and reference manuals in both printed
and electronic forms free of charge for all Software. All such sets
of instructions and reference manuals are ordered as separate line
items. Licensee may purchase additional sets at the price and
discount specified on Schedule C. Planning guides are available and
----------
will be delivered free of charge with
-24-
each and every Release delivered to Licensee.
13.9 Transfer of License.
-------------------
(a) Qwest may transfer, assign or sublicense (such sublicense only to
the extent (***) to (***) those rights (***) to use the
Products), any license granted by Supplier hereunder, to any
Affiliate, holding company, subsidiary of holding company,
subsidiary, associated company, or successor in interest of Qwest
or any person controlling or controlled by any of the foregoing
or to any person directly or indirectly under common control
with Qwest (collectively, "License Transferee"), provided such
License Transferee (i) has (***) to be (***) by the (***) of
(***) and (ii) of which (***) has (***).
(b) Qwest and any successor to Qwest's title in any Products shall
have the right without further consent of Supplier to assign or
sublicense (such sublicense only to the extent necessary to grant
those rights necessary to use the Products), the License herein
granted to any other party who subsequently acquires the right to
use the applicable Products, provided that any such other party
prior to the transfer of the applicable Software (***) the terms
and conditions of this license.
14. TECHNOLOGY CURRENCY
Supplier understands and acknowledges that Qwest is entering into this
obligation (including but not limited to the incorporated pricing and
discount terms) based on the expectation that Supplier will (***) (i)
continue to remain technologically competitive and (ii) offer products to
Qwest that will allow productivity savings, based on Qwest's use of such
products. Supplier shall (***) provide products using current technologies
that will enable Qwest to take advantage of technological advancements in
its industry and support Qwest's efforts to remain competitive in the
markets in which it competes.
15. INFRINGEMENT WARRANTY AND INDEMNITY
15.1 Supplier warrants that it or its Affiliates are the owner of the
Intellectual Property Rights of the Products, or, if the Products or
other materials contain third party products or software, that
Supplier has the full power and authority to deliver, convey and grant
to Qwest the related license and other rights granted under this
Agreement. Supplier further warrants that Supplier's provision of
Services under this Agreement, grant of the licenses hereunder, and
Qwest's use of the Products will not constitute a
-25-
misappropriation of any trade secrets, infringement or
misappropriation of any copyright or trademark or (***) any patent.
15.2 Supplier shall defend or settle, at its expense, any threatened or
actual claim, suit or proceeding made against Qwest that use of the
Products infringes any patent, trademark, copyright, trade secret or
other intellectual property right of a third party ("Infringement
------------
Claim"), and shall indemnify Qwest and hold it harmless against all
-----
damages, claims, costs of investigation, litigation, settlements,
judgments and disbursements, including reasonable attorneys' fees
("Losses") arising out of the foregoing. In order for this
------
indemnification to apply to a claim, Qwest shall give Supplier prompt
notice following Qwest's knowledge of any such Infringement Claim,
shall allow Supplier to control the defense of and settlement
negotiations with regard to such claim, provided that Qwest shall
approve the terms of any settlement or compromise with respect to any
Infringement Claim directed to Qwest's use of the Product unless
Supplier has the (***) the settlement or compromise. The Parties
shall provide reasonable cooperation and assistance in the defense of
the Infringement Claim.
15.3 If any Product furnished under this Agreement becomes, or in Qwest or
Supplier's reasonable opinion is likely to become, the subject of any
claim, suit, injunction or proceeding arising from or alleging
infringement of, or in the event of any adjudication that such Product
infringes on, any Intellectual Property Right, Supplier, at its
expense, shall take the following actions in the listed order of
preference:
(a) (***) procure in a timely manner for Qwest and its Affiliates (if
applicable) the right to continue using the Product (***) or
(***) of (***) or (***); or if those efforts are unavailing;
(b) (***) replace or modify the Product to make it non-infringing;
provided, however, that such modification or replacement shall
not materially degrade the operation or materially impair the
performance of the Product, or otherwise make it incompatible
with Qwest's current network; or
(c) if (a) and (b) are commercially impracticable or would cause the
Products to fail to be Network Compatible, accept return of the
Product and refund Qwest all amounts paid therefor, including any
prepaid maintenance and support fees, and pay Qwest any
additional costs incurred by Qwest in acquiring a comparable
replacement for the infringing Product. Any refund of amounts
paid may be reduced based on depreciation of the Product on
-26-
straight line basis over a (***).
15.4 Supplier shall have no liability in respect of any Infringement Claim
based on the use of a Product to the extent that such claim (i) is
based on a use of a Product by Qwest in a manner or for a purpose not
contemplated by this Agreement; (ii) is based on a use of the Product
by Qwest in combination with other non-Supplier products where such
combination is not reasonably contemplated by this Agreement,
provided the Infringement Claim arises solely from such combination;
or (iii) is based on a modification of the Product by Qwest where
such modification has not authorized by Supplier in writing.
15.5 This Section 15 establishes the entire rights and obligations of the
Parties for claims of infringement of Intellectual Property Rights.
16. KNOW HOW AND NEW TECHNOLOGY
Notwithstanding anything to the contrary contained in this Agreement, each
Party shall be entitled, without royalty to the other Party, to use,
disclose and sell any know-how retained in the minds of employees of such
Party, expertise, techniques, approaches or concepts (the "Know-how")
--------
developed or acquired in the course of performing under this Agreement. The
Parties agree that Know-how shall not include any Qwest, Supplier or third
party (***) and (***) or (***), any (***), or any Confidential Information
of the other Party. The foregoing shall not be construed as granting a
license in any Intellectual Property Rights. The Parties recognize that New
Technology may be developed during the Term. If any New Technology is
deemed by the Party that created it to be deserving of intellectual
property protection, then that Party is responsible for taking steps to
protect any interests it may have in such New Technology and may (***) such
New Technology during its pursuit of Intellectual Property Rights in the
same.
17. WARRANTY
17.1 Equipment
(a) Supplier warrants that Equipment supplied hereunder will be
Operative and free from defective material and faulty
workmanship for (***) from the (***) stamped on the Equipment
or, if the date of shipment is not marked on the Equipment,
(***) from the (***) ("Warranty Period").
(b) The foregoing Equipment warranty shall not apply to the extent
that (i) the Nonconformity is caused by the Equipment having
been
-27-
altered or repaired by any party other than Supplier without
Supplier's prior, written consent; (ii) the Nonconformity
results from Qwest's (***) of the Equipment; or (iii) the
Equipment having been damaged by (***). This foregoing Equipment
warranty does not apply to items normally consumed in operation,
such as, but not limited to, lamps and fuses.
(c) If a Nonconformity occurs, Qwest shall give Supplier a reasonable
opportunity to repair or replace such Equipment, as set forth in
Schedule H, before exercising any other rights or remedies it may
----------
have under this Agreement.
(d) Supplier shall provide technical support for a Product performed
by qualified and competent personnel for a period of (***) after
Acceptance of the Product as set forth in Schedule G.
----------
17.2 Supplier warrants the Software, but not including embedded software
or firmware (which is addressed in Section 17.1), will be Operative
through the (***) after the (***) of the Software, provided that the
foregoing warranty shall not apply if Qwest has (***) for (***) which
would (***) of (***) and (***) to (***) such Releases. At Qwest's
option, Supplier shall provide software maintenance and support after
the initial Warranty Period pursuant to the terms and conditions of
the Software Maintenance Agreement, attached hereto as Schedule I.
----------
17.3 Supplier warrants that the Software, ISUs, Enhancements, Releases
and Versions and any media used to distribute it does not contain any
computer instructions, circuitry, routines or other technological
means ("Harmful Code") whose purpose is to disrupt, damage or
------------
interfere with Qwest's use of its computer and telecommunications
facilities for their commercial, test or research and development
purposes. Supplier shall indemnify Qwest and hold Qwest harmless from
and against any and all claims, losses, costs, liabilities, damages
and/or expenses, including reasonable attorneys fees, arising from
the presence of Harmful Code in or with the Software or contained on
media delivered by Supplier.
17.4 Supplier shall perform all Services required under this Agreement
including without limitation, customization services, implementation,
maintenance services and training services in a good and workmanlike
manner and shall be responsible for the capabilities, limitations and
performance of any development tools used in providing its Services.
With Qwest's prior written consent, Supplier may perform its (***)
hereunder through an agent.
-28-
17.5 Supplier warrants during the Warranty Period that the Products
provided hereunder shall be able to accurately process data
(including without limitation, calculating, compiling and sequencing
date data) from, into and between the twentieth and twenty-first
centuries, including leap year calculations, and will create, store,
process and exchange (input and output) information related to or
including dates on or after January 1, 2000, without error or
omissions ("Year 2000 Compliant").
-------------------
17.6 The Warranty Period for any replacement Product provided by Supplier
under this Agreement shall be the greater of (i) the remaining
Warranty Period of the replaced Product on the date it went out of
service; or (ii) an additional Warranty Period of (***) from the date
of Acceptance of the replacement Product by Qwest.
17.7 Upon expiration of the applicable Warranty Period for Equipment
furnished hereunder, repair and replacement service for such
Equipment shall be available to Qwest from Supplier in accordance
with Schedule C and at charges (***).
----------
17.8 The warranty for any third party items used in the Product shall be
no less than the warranties for the rest of the Product. As of the
Effective Date, there are not currently any third party items used in
the Product that have a longer warranty period than the Warranty
Period. If any third party items used in the Product have a longer
warranty than granted herein then, to the extent permitted by the
manufacturer, Supplier shall assign warranties for third party items
which have a warranty period exceeding the Warranty Period to Qwest.
17.9 Supplier represents and warrants that as of the Effective Date of
this Agreement, the Supplier has not received written notice of any
pending lawsuits, claims, disputes or actions that it reasonably
considers significant (i) alleging that the Products infringe or
misappropriate any Intellectual Property Rights, or (ii) adversely
affecting the Products or Supplier's ability to undertake and perform
its obligations under this Agreement.
17.10 During the Warranty Period for a Product, Supplier shall provide
warranty support services performed by qualified and competent
personnel as set forth in Schedule H. Supplier shall deliver to
----------
Qwest and keep current a list of persons and telephone numbers
("Calling List") for Qwest to contact in order to obtain answers to
------------
questions arising, or assistance in solving problems or
Nonconformities occurring, during Qwest's use of any of the Products.
The Calling List shall include (i) the first person to contact if a
question arises or problem occurs, and (ii) the persons in
successively more responsible or qualified positions to provide the
answer or assistance
-29-
desired. If Supplier does not respond promptly to any request by
Qwest for telephone assistance, then Qwest may attempt to contact
the next more responsible or qualified person on the Calling List
until contact is made and a designated person responds to the call.
17.11 After Qwest reports a suspected Nonconformity, Supplier shall
provide a correction or work around or repair part to restore the
Product (including the entire System) to Operative condition as soon
as reasonably possible, but in any case in conformance with the
designated repair times in the Specifications in the applicable
Schedules to this Agreement.
17.12 Any Release made available to any of Supplier's customers within the
Warranty Period for any Product that correct Nonconformities shall
be provided to Qwest at no additional charge. Such Release shall be
in compliance with the performance and warranty requirements for any
of the Products under this Agreement.
17.13 Supplier warrants that the Products: (i) will meet all applicable
standards including, but not limited to, ANSI and ISO Standards;
(ii) will provide the functionality described in; (iii) will conform
to the current environmental specifications set forth in the
Bellcore New Equipment Building Standard; and (iv) will be Network
Compatible.
17.14 THE EXPRESS WARRANTIES IN THIS AGREEMENT INCLUDING THE SCHEDULES
ATTACHED HERETO ARE IN LIEU OF ANY OTHER WARRANTY, WHETHER EXPRESS,
IMPLIED OR STATUTORY, WITH RESPECT TO THE PRODUCT TO BE SUPPLIED
UNDER THIS AGREEMENT. EXCEPT AS EXPRESSLY SET FORTH HEREIN, SUPPLIER
SPECIFICALLY DISCLAIMS THE IMPLIED WARRANTIES OF MERCHANTABILITY,
FITNESS FOR A PARTICULAR PURPOSE, NON-INFRINGEMENT OF THIRD PARTY
RIGHTS AND THOSE ARISING FROM A COURSE OF DEALING OR USAGE OF TRADE.
SUPPLIER NEITHER ASSUMES NOR AUTHORIZES ANY PERSON TO ASSUME FOR IT
ANY OTHER LIABILITY. THE WARRANTIES EXPRESSED HEREIN SHALL NOT BE
ASSIGNABLE TO ANY OTHER PARTY EXCEPT AS SUCH PRODUCTS OR OTHER
RIGHTS ARE ASSIGNED OR OTHERWISE TRANSFERRED PURSUANT TO THE TERMS
AND CONDITIONS OF THIS AGREEMENT.
18. GENERAL INDEMNITY
(***) shall indemnify and hold harmless (***) from any claim or damages due
to the personal injury or death of any individual and against any
reasonably
-30-
foreseeable loss, damage, liability, cost or expense (including attorneys'
fees) which may be incurred on account of any suit, claim, judgment,
demand, or threat thereof, arising out of or caused by a willful or grossly
negligent act or omission or an intentional act of misconduct of (***), its
agents, employees or subcontractors.
19. LIMITATION OF LIABILITY
NEITHER PARTY SHALL BE LIABLE TO THE OTHER (OR ANYONE CLAIMING UNDER OR
THROUGH THE OTHER) FOR ANY SPECIAL, INDIRECT, CONSEQUENTIAL, PUNITIVE
OR EXEMPLARY DAMAGES ARISING FROM OR RELATED TO THIS AGREEMENT,
INCLUDING, BUT NOT LIMITED TO, LOST PROFITS OR OTHER ECONOMIC
ADVANTAGE, EVEN IF THE PARTIES HAVE KNOWLEDGE OF THE POSSIBILITY OF
SUCH DAMAGES. PROVIDED, HOWEVER, THAT IF THE LAW OF ANY JURISDICTION
APPLICABLE TO THIS AGREEMENT DOES NOT PERMIT SUCH DAMAGES TO BE
COMPLETELY DISCLAIMED, THIS CLAUSE SHALL BE INTERPRETED AS NECESSARY
TO GIVE THE FULL BENEFIT OF ANY DISCLAIMER OR LIMITATION OF SAID
DAMAGES AS PERMITTED UNDER SUCH LAW. THE FOREGOING LIMITATION SHALL
NOT APPLY IN THE EVENT OF LIABILITY ARISING FROM: (i) AN INDEMNITY
UNDER SECTION 15 ("INFRINGEMENT WARRANTY AND INDEMNITY"), SECTION 17.3
("HARMFUL CODE INDEMNITY") OR SECTION 18 ("GENERAL INDEMNITY"); (ii) A
BREACH OF SUPPLIER'S CONFIDENTIALITY OBLIGATIONS IN SECTION 20
("CONFIDENTIALITY"); OR (iii) THE GROSS NEGLIGENCE OR WILLFUL
MISCONDUCT OF A PARTY, ITS AGENTS, ITS EMPLOYEES OR NOMINEES ARISING
OUT OF OR IN CONNECTION WITH THIS AGREEMENT.
20. CONFIDENTIALITY
20.1 This Agreement and all information marked as confidential and
disclosed by either Party (the "Disclosing Party") to the other (the
"Recipient"), or information of a confidential nature which is
disclosed orally and for which a written summary is provided to the
other Party (***) of (***) (provided that no written summary shall be
required for confidential information of a (***) which is disclosed
orally between the Parties' (***) which such personnel should
reasonably understand to be confidential) shall be "Confidential
------------
Information". Confidential Information constitutes a valuable asset
-----------
of and is proprietary to the Party disclosing or originally
-31-
possessing it. Supplier acknowledges that Qwest keeps its customers'
records strictly confidential. Supplier and its Representatives shall
keep strictly confidential any Qwest customer records, whether or not
they are marked as confidential. Neither Party shall willfully
disclose Confidential Information or knowingly permit its
Representatives to disclose Confidential Information to any person
other than persons, including its Representatives, having a specific
need to know in performance of the work. Each Party shall take
reasonable care to insure fulfillment of this obligation, including
instructing its Representatives not to sell, lease, assign, transfer,
use outside their scope of employment or reveal any Confidential
Information or Qwest customer records without prior written consent of
the other Party. Recipient shall use the Disclosing Party's
Confidential Information only for purposes of exercising its rights or
fulfilling its obligations under this Agreement and shall disclose
Confidential Information only to those (***) and (***) who have a need
to know Confidential Information for purposes of this Agreement.
Recipient shall return or destroy the Confidential Information
(including all copies) when no longer needed or when requested to do
so by the Disclosing Party Each Recipient shall take reasonable care
to insure fulfillment of this obligation, including instructing its
Representatives not to sell, lease, assign, transfer, use outside
their scope of employment or reveal any Confidential Information,
including but not limited to customer records, without prior written
consent of the Disclosing Party.
20.2 If a subpoena or other legal process in any way concerning
Confidential Information is served upon Recipient, the Recipient shall
notify the Disclosing Party promptly, and the Recipient shall
cooperate with the Disclosing Party, at the latter's expense, in any
lawful effort to contest the validity of such subpoena or other legal
process.
20.3 Notwithstanding the foregoing, if either Party is required by law or
governmental regulation by compulsory judicial or administrative
process to make any disclosure, including but not limited to those
made in any registration statement, report or other document filed
with the U.S. Securities and Exchange Commission or any other
governmental agency, such disclosure will not be deemed to violate the
terms of this Section, provided the Recipient promptly notifies the
Disclosing Party of such disclosure and (***) to (***) a (***) or to
(***) to protect the intent of the Parties to restrict disclosure of
all Confidential Information and the terms of this Agreement,
including but not limited to seeking confidential treatment of all
such information in administrative filings. In addition, if the
Recipient's efforts to seek confidential treatment or other protective
measures for such information are not successful, such party may only
-32-
make such disclosure after (i) providing written notice of the same to
the disclosing party and (ii) (***) the Disclosing Party to take
measures to secure the confidential treatment of the information.
20.4 Qwest may disclose the Software to its contractors who have a need to
know for purposes of exercising rights related to this Agreement,
provided that such contractors have agreed in writing to observe in
substance the obligations of Qwest set forth in this Section.
20.5 The obligations of confidentiality in this Section shall not apply to
any information which a Party has in its possession when disclosed to
it by the Disclosing Party, information which a Party independently
develops, information which is or becomes known to the public other
than by breach of this Agreement or information rightfully received by
a Party from a third party without the obligation of confidentiality.
20.6 A Party shall not use the other Party's name or logo or refer to the
other Party directly or indirectly in any advertising, sales
presentation to any other person, news release, release to any
professional or trade publication or for any other similar purpose
without the other Party's prior written approval, provided that (i)
Supplier may use Qwest's name or logo, or both, in a list of
Supplier's customers, if such use does not imply endorsement and (ii)
Qwest may use Supplier's name or logo, or both, in a list of Qwest's
suppliers.
21. TERMINATION, SURVIVAL
21.1 Bankruptcy. Either Party may terminate the Agreement if the other
----------
Party shall: (a) file a voluntary petition under any bankruptcy or
insolvency law, or file a voluntary petition under the reorganization
or arrangement provisions of any law of any jurisdiction, or have
proceedings under any such laws instituted against it which are not
terminated within (***) of such commencement; (b) become insolvent,
bankrupt, or admit in writing of its inability to pay all debts as
they mature or make a general assignment for the benefit of or enter
into any composition or arrangement with creditors; (c) authorize,
apply for, or consent to the appointment of a receiver, trustee, or
liquidator of all or a substantial part of its assets, or has
proceedings seeking such appointment commenced against it which are
not terminated within (***) of such commencement.
21.2 Termination for Convenience. Qwest may terminate or suspend this
---------------------------
Agreement or a part thereof for convenience upon (***) written notice,
and Qwest shall have no further obligations under this Agreement
except for (i) payment due for any Products retained by Qwest for
which Supplier
-33-
has not received payment; (ii) payment due for any Services completed
by Supplier for which Supplier has not received payment and (iii)
payment of the difference between the (***) (as such amount exists as
of the date of termination) and the amount of payments received by
Supplier.
21.3 Purchase Commitments of Acquired Entities. If, during the Term of
-----------------------------------------
this Agreement, Qwest or any of its Affiliates acquire a controlling
interest in or substantially all the assets of an entity ("Acquired
--------
Entity") that has an agreement with Supplier for products, services
------
and/or software with remaining purchase commitments, Qwest may satisfy
such purchase commitments under the original agreement between the
Acquired Entity and Supplier or this Agreement provided that any
amounts purchased by Qwest or its Affiliates that apply to the
satisfaction of a purchase commitment in another agreement (***) the
Commitment.
21.4 Change of Control. If, during the Term of this Agreement, an entity,
-----------------
person or successor acquires 50% or more of Qwest's voting securities
or all or substantially all of its assets whether by merger,
consolidation, reorganization or sale of assets then the acquiring
entity, person or successor shall have the right to terminate this
Agreement or a part thereof upon (***) written notice, and Qwest shall
have no further obligations under this Agreement except for (i)
payment due for any Products retained by Qwest for which Supplier has
not received payment; (ii) payment due for any Services completed by
Supplier for which Supplier has not received payment and (iii) payment
of the difference between the (***) (as such amount exists as of the
date of termination) and the amount of payments received by Supplier.
21.5 Termination for Cause. Notwithstanding any other provision of this
---------------------
Agreement, prior to any Party's termination or suspension for cause,
the Parties shall use the dispute resolution procedure set forth in
Section 25. The foregoing requirement shall apply only until the total
Commitment amount has been paid by Qwest. Either Party may terminate
or suspend this Agreement upon material breach of this Agreement by
the other after providing written notice to the other Party describing
specific obligations the other Party has materially breached. Upon the
breaching Party's receipt of the other Party's notice, the breaching
Party shall have (***) to cure the breach. If the breaching Party is
unable to cure such breach within such (***) period, the other Party
may terminate or suspend this Agreement in whole or part; provided
that any such termination shall relieve (***) of (***) under (***).
21.6 Survival. All provisions of this Agreement which by their nature
--------
must survive termination in order to achieve the fundamental purposes
of this Agreement shall survive any termination of this Agreement,
including but
-34-
not limited to the following Sections: 2 (Scope), 3 (Supplier
Obligations), 9 (Payment Terms), 13 (Software), 15 (Infringement
Warranty and Indemnity), 16 (Know-How and New Technology), 17
(Warranty), 18 (General Indemnity), 19 (Limitation of Liability), 20
(Confidentiality), 21 (Termination), 31 (Severability) and 33 (Choice
of Law).
22. FORCE MAJEURE
22.1 Except to the extent of normal inclement weather, which shall be
built into any schedule, neither Party will be liable for delays in
performance or a failure to perform hereunder due to causes of acts
of God, acts of any government, wars, riots, fires, floods,
accidents, strikes, or embargoes. In the event of such delays, the
schedules shall be extended for such additional period of time as is
determined to be equitable by the Parties. With respect to labor
difficulties, a Party shall not be obligated to accede to any demands
being made by employees or other personnel.
If any performance date for any Product or Service under this
Agreement is postponed or extended pursuant to this Section for
longer than (***), Qwest may, at its option, by written notice given
during the postponement or extension, terminate Supplier right to
render further performance for such affected Products or Services
after the effective date of termination without liability for that
termination.
23. JOINT WORK PRODUCT
The Parties, who have both been represented by legal counsel, have jointly
participated in negotiating and drafting this Agreement, including its
Schedules and any attachments. In the event an ambiguity or question of
intent or interpretation arises, this Agreement shall be construed as if
jointly drafted by the Parties and no presumption, inference or burden of
proof shall arise favoring or disfavoring a Party by virtue of authorship
of any or all of the Agreement provisions.
24. ASSIGNMENT
24.1 Subject to Section 13.9 ("Transfer Of License"), except as provided
below, neither Party shall assign any of its rights nor delegate any
of its obligations under this Agreement without the prior express
written consent of the other Party. Any prohibited assignment or
delegation shall be null and void.
24.2 Qwest may assign this Agreement without prior approval to any company
-35-
or Entity controlling, controlled by or under common Control of Qwest
or its Affiliates which assignee is (***) to (***) obligations
hereunder. In addition and notwithstanding the foregoing, Qwest may
assign this Agreement without the approval of Supplier to any
successor in interest resulting from a merger, acquisition,
reorganization or transfer of all or substantially all of Qwest's
business with or to a successor.
25. DISPUTES
25.1 The Parties shall work together and attempt to resolve by good faith
and diligent negotiation any dispute, controversy or claim between
them arising out of or relating to any contract document, or the
breach, termination or invalidity thereof (a "Dispute"). The Parties
-------
shall work together in good faith to informally resolve the dispute
internally by escalating it as necessary to progressively higher
levels of management. Following such internal process, if the dispute
has not been resolved within (***) after formal initiation of the
dispute process, either Party may initiate arbitration as provided for
below.
25.2 Following the procedure discussed in Section 25.1 above, binding
arbitration shall be used to resolve any Dispute. Such arbitration
shall be conducted in accordance with the then-current Commercial
Arbitration Rules of the American Arbitration Association ("AAA
---
Rules") by (***). Within (***) of a notice of arbitration, each Party
shall appoint (***) and the arbitrators appointed shall together
appoint a (***). Once the (***) arbitrator has (***) appointment, the
arbitrators shall be deemed a panel (hereinafter, the "Impanelment").
25.3 The Federal Arbitration Act, 9 U.S.C. Secs. 1-16 shall govern the
arbitrability of all Disputes. The arbitration proceedings shall be
English and the place of arbitration shall be Denver, Colorado. The
construction and interpretation of this Agreement shall be governed by
the laws of the State of Colorado without reference to its conflicts
of law rules, or rules of statutory arbitration. Arbitral awards under
this Section 25 shall be final and binding, and shall be enforceable
in any court having jurisdiction. The arbitration shall (***) of the
(***).
25.4 (a) Nothing in this Section will prevent any Party from applying to
any court of competent jurisdiction for preliminary or interim relief
in a judicial proceeding if such relief from a court is necessary to
preserve the status quo pending resolution or to prevent serious and
irreparable injury to that Party pending resolution of the Dispute
through arbitration, or to compel arbitration in accordance with this
Section.
-36-
(b) For purposes of this Section each Party consents to the exclusive
jurisdiction and venue of the courts of the state and federal courts
of Denver County in the State of Colorado.
(c) The prevailing Party in an arbitration or litigation shall be
entitled to recover from the other Party reasonable attorneys' fees
and other costs of such arbitration.
(d) The arbitrator shall have, in addition to any other powers set forth
herein or in the rules and statutory sections referenced herein, the
power to modify or eliminate the Commitment and / or the dates related
thereto.
26. RELATIONSHIP OF THE PARTIES
26.1 The Parties are independent contractors. Nothing in this Agreement or
in the activities contemplated by the Parties pursuant to this
Agreement shall be deemed to create an agency, partnership, employment
or joint venture relationship between the Parties. Each Party shall be
deemed to be acting solely on its own behalf and, except as expressly
stated, has no authority to pledge the credit of, or incur obligations
or perform any acts or make any statements on behalf of, the other
Party. Neither Party shall represent to any person or permit any
person to act upon the belief that it has any such authority from the
other Party. Neither Party's officers or employees, agents or
contractors shall be deemed officers, employees, agents or contractors
of the other Party for any purpose.
26.2 Supplier represents and warrants that Supplier qualifies as an
independent contractor under the provisions of the Internal Revenue
Code's common law rules enacted as part of Section 1706 of the 1986
Tax Reform Act, and as such Supplier is filing all required forms and
necessary payments appropriate to Supplier's tax status. In the event
Supplier's independent status is denied or changed and Supplier is
declared to have "common law" status with respect to work performed
for Qwest, Supplier agrees to indemnify, defend and hold Qwest and its
Affiliates harmless from all costs, including legal fees, which Qwest
may incur as a result of such change in status.
27. AMENDMENT
No changes, amendments or modifications of any of the terms or conditions of
this Agreement shall be valid unless made by an instrument in writing signed
by both Parties. None of the terms or conditions of this Agreement shall be
modified, amended or altered by or through a Purchase Order. Each Party
shall
-37-
designate by written notice to the other Party the individual who has the
authority to amend this Agreement.
28. COMPLIANCE WITH LAWS
The Parties shall comply with all applicable federal, state and local laws,
regulations and ordinances as they relate to this Agreement and the
Software, including, but not limited to, the regulations of the United
States Government, the provisions of Executive Order 11246 (as amended) of
the President of the United States on Equal Employment Opportunity and the
rules and regulations issued pursuant thereto, which are incorporated in
this Agreement by this reference as if set forth in full. Supplier and the
Products shall comply with all rulings, orders and determinations by the
Federal Communications Commission and any other governmental body relating
to the provision of the Products or Services under the (***).
29. CONSTRUCTION/HEADINGS
All Schedules and attachments, as supplemented and amended, to this
Agreement or to be attached to this Agreement are made a part of it as if
fully included in the text of this Agreement. References to any law,
legislative act, rule or regulation shall mean references to such law,
legislative act, rule or regulation in changed or supplemented form or to a
newly adopted law, legislative act, rule or regulation replacing a previous
law, legislative act, rule or regulation. All defined terms used in the
Agreement shall have the same meanings ascribed to them when used in the
Schedules, attachments and Purchase Orders, unless otherwise specified
therein. The terms "including" or "includes" shall always be construed as
meaning respectively "including without limitation" or "includes without
limitation". The title, captions and headings used in this Agreement are
strictly for convenience of reference only and shall not be used in the
interpretation, construction, amplification or limitation of any of the
content of this Agreement. Whenever the singular is used herein, the same
shall include the plural where appropriate, and when the plural is used
herein, the same shall include the singular where appropriate.
30. NO WAIVER
No delay, failure or waiver of either Party's exercise or partial exercise
of any right or remedy under this Agreement shall operate to limit, impair,
preclude, cancel, waive or otherwise affect such right or remedy.
31. SEVERABILITY
-38-
If any provision of this Agreement is held invalid, illegal or
unenforceable, the validity, legality or enforceability of the remaining
provisions shall in no way be affected or impaired thereby.
32. COUNTERPARTS
This Agreement may be executed by the Parties in one or more counterparts,
and each of which when so executed shall be an original, but all such
counterparts shall constitute one and the same instrument.
33. CHOICE OF LAW
This Agreement is entered into in and shall be governed by the internal
laws and of the (***) without regard to the principles of choice of law
thereof. The Products shall be deemed to be goods within the meaning of
the Uniform Commercial Code. Each Party agrees to waive its right to a
jury trial in any action commenced hereunder.
34. REMEDIES
The remedies under this Agreement shall be cumulative and not exclusive,
and the election of one remedy shall not preclude pursuit of other remedies
generally available under the governing law.
35. IMMIGRATION REFORM AND CONTROL ACT
Supplier warrants, represents, covenants and agrees that it will not assign
to perform any efforts under this Agreement any individual who is an
unauthorized alien under the Immigration Reform and Control Act of 1986 or
its implementing regulations. Supplier shall indemnify and hold harmless
Qwest, its parent, subsidiaries and affiliated companies from and against
any and all liabilities, damages, losses, claims or expenses (including
attorneys' fees) arising out of any breach by Supplier of this section. In
the event any Supplier Personnel or contractor working under this
Agreement, or other individuals providing work to Qwest on behalf of
Supplier under this Agreement, are discovered to be unauthorized aliens,
Supplier will immediately remove such individuals from performing work and
replace such individuals with individuals who are not unauthorized aliens.
36. IMPORT/EXPORT
The Parties hereby represent and warrant that no commodities or technical
data (including computer software) or other technology agreed to be sold or
otherwise
-39-
transferred under this Agreement will be knowingly sold, leased, delivered,
transferred or conveyed to any person in any country except in strict
compliance with all export and import laws, regulations, executive orders
or decrees of the United States Government or any agencies thereof and the
government of any other country (or any agencies thereof) with jurisdiction
over such transaction. Qwest shall, solely at its own expense, obtain all
required export and import licenses, permits, approval, certificates and
verifications before shipment of any Products.
37. PUBLICITY
Neither Party shall, without the prior written approval of the other Party,
publicly disclose in any press release, filing (including without
limitation any SEC filing), brochure or document any information pertaining
to this Agreement, provided that in the event of a conflict between this
Section and (***) shall control.
38. NOTICES
38.1 In addition to those instances identified throughout this Agreement
that require notices to particular individuals via particular means
for particular purposes, all notices, requests, demands, or consents
required or permitted hereunder, other than routine operational
communication, shall be in writing and shall be delivered, sent by
facsimile transmission or overnight courier, or sent by certified or
registered mail to the respective Party at the addresses set forth
below or at such other address as shall have been given to the other
Party in writing for the purposes of this Section and Agreement. Such
notices and other communications shall be deemed effective upon the
earliest to occur of (i) actual delivery of confirmed facsimile or
electronic transmission; (ii) three (3) postal delivery days after
the date of mailing by certified or registered mail, return receipt
requested, postage prepaid; (iii) one (1) business day after dispatch
via an express courier with a reliable system for tracking delivery;
(iv) actual delivery by
-40-
hand.
(a) If to Supplier:
Tellium, Inc.
0 Xxxxxxxx Xxxxx
Xxxxxxxxx XX 00000
Attn: Xxxxxxx Xxxxx, CFO & Secretary
If to Qwest:
Qwest Communications Corporation
000 00/xx/ Xxxxxx
Xxxxxx, Xxxxxxxx 00000
Attention: Vice President, Procurement
With a copy to:
Qwest Communications Corporation
000 00/xx/ Xxxxxx
Xxxxxx, Xxxxxxxx 00000
Attention: Legal
38.2 A Party may from time to time change its address for notification
purposes by giving the other Party prior written notice of the new
address and the date upon which it will become effective, in
accordance with the manner set forth in this Section.
39. INSURANCE REQUIREMENTS
39.1 During the Term, Supplier and any of its subcontractors shall maintain
insurance of the kinds and in the amounts specified below with
insurers of recognized responsibility, whose policies are valid in the
states where the work is being performed.
39.2 In accordance with the above, Supplier and any subcontractors shall
maintain the following insurance coverages:
(a) Comprehensive general liability insurance.
Commercial general liability insurance with a combined single limit
for bodily injury and property damage of (***) each occurrence
and General and Products Liability aggregates of (***) each,
covering all operations and/or work performed under this
Agreement.
(b) Business automobile liability insurance.
Business automobile liability with a combined single limit for bodily
injury and property damage of (***) each occurrence to include
coverage for all owned, non-owned, and hired vehicles.
(c) Worker's compensation and employers' liability insurance.
Worker's compensation insurance complying with the law of the State or
-41-
States of operation, whether or not such coverage is required
by law, and employer's liability insurance with limits of (***)
each employee and (***) disease policy limit.
Certificates of such insurance shall be submitted to Qwest naming Qwest as
an additional insured prior to the start of any work associated with this
Agreement. These certificates shall provide that there will be no
termination or non-renewal of such coverage without thirty (30) days prior
written notice to Qwest, in which case Supplier shall still maintain
insurance and which may require certificate, and in no case where this
Agreement is still in effect.
Supplier shall require each subcontractor to provide and maintain at all
times during the term of this Agreement insurance equivalent to that which
is required of Supplier. Any subcontractor and any subcontractors'
carriers shall waive all right to recovery against Qwest for any injuries
to persons or damage to property in the execution of work performed under
this Agreement, exclusive of such liability resulting from Qwest's
negligence or intentional misconduct and within the limits of any
applicable laws.
Should Supplier at any time neglect or refuse to provide the insurance
required, or should such insurance be canceled or non-renewed, Qwest shall
have the right to purchase such insurance, and the cost shall be billed to
Supplier. In addition, should Supplier at any time neglect or refuse to
pay the necessary premium, Qwest shall have the right to deduct this amount
from monies due Supplier.
40. ORDER OF PRECEDENCE
In the event of an inconsistency between the terms and conditions of the
Agreement and the Schedules attached hereto, the Agreement shall control.
41. ENTIRE AGREEMENT
41.1 This Agreement, together with any other instrument, agreement or
document attached or referred to, which are incorporated by this
reference as though set forth in full, embodies the final, full and
exclusive statement of the agreement between Qwest and Supplier, as
it relates to the subject matter hereof. Neither Party shall be bound
by or liable to the other Party for any representation, promise or
inducement made by any agent or person in their employ relating to
subject matter which is not embodied in this Agreement.
41.2 The terms of this Agreement shall prevail over all preprinted forms,
including Purchase Orders, software shrink wrap licenses and
invoices, as any terms and conditions on such preprinted forms shall
be null and void
-42-
unless otherwise agreed to in writing by both Parties.
* * *
IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be duly
executed as of the Effective Date, such Parties acting by their officers, being
thereunto duly authorized.
Tellium, Inc. Qwest Communications Corporation
By:________________________ By:_________________________
Title:_____________________ Title:______________________
Date:______________________ Date:_______________________
-43-
SCHEDULE A
----------
APPROVED AFFILIATES
-------------------
-44-
SCHEDULE B
----------
Purchase Order
Qwest Communications Purchase Order Date Revision Page
000 00xx Xxxxxx PO:(***) (***) 1 of 1
Xxxxxx, XX 00000 Payment Terms Freight Terms Ship Via
United States (***)
Buyer: ______________ Currency Code: (***)
Ship To: SEE COMMENTS BELOW FOR
FURTHER INSTRUCTIONS
Vendor: Example## United States
Example Company
XX Xxx 000
Xxxxxx, XX 00000-0000
Xxxxxx Xxxxxx Xxxx To: Qwest Communications
000 Xxxxxxxxxxx Xxxxxx
Xxxxx 0000
Xxxxxx, XX 00000
Xxxxxx Xxxxxx
Tax Exempt? (***) Tax Exempt ID:
Line-SchdItem Description Mfg ID Quantity(***) PO Price Extended Amt Due Date
(***) (***) (***) (***) (***)
(***)
Services performed by (***) under direction of the (***) - (***)
(***)
Total PO Amount (***)
PLEASE FAX ORDER ACKNOWLEDGEMENT TO (***). IF ACKNOWLEDGEMENT IS NOT RECEIVED
WITHIN (***).
(***) THE (***) THE (***).
Supplier, all invoices (***) the (***) in (***) due to the (***) in (***).
(***)/(***)
Acting as agent for: (***)
-45-
(***)
(***), and (***) must be (***)
(***) will (***) unless
(***) by (***).
-46-
SCHEDULE C
----------
PRODUCT PRICE LIST
-------------------
Aurora Optical Switch Configuration and Pricing
--------------------------------------------------------------------------------
Price
--------------------------------------------------------------------------------
Module Per Module
--------------------------------------------------------------------------------
OC48 Transceiver (***)
--------------------------------------------------------------------------------
OC-192 SR Transceiver (***)
--------------------------------------------------------------------------------
OC-192 LR Transceiver (***)
--------------------------------------------------------------------------------
Shelf Controller Module (***)
--------------------------------------------------------------------------------
First/Third Switch Module (***)
--------------------------------------------------------------------------------
Middle Switch Module (***)
--------------------------------------------------------------------------------
TR Bay Common (***)
--------------------------------------------------------------------------------
-47-
--------------------------------------------------------------------------------
Switch Bay Left Common (***)
--------------------------------------------------------------------------------
Switch Bay Right Common (***)
--------------------------------------------------------------------------------
Blank (***)
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
Software per System
--------------------------------------------------------------------------------
AOS Software A-Z Prov. OC-192 Groom (Upgrade from R1.0) (***)
--------------------------------------------------------------------------------
AOS Software Mesh R2.0 (Mesh, Prov, SDH) (Upgrade from R1.1) (***)
--------------------------------------------------------------------------------
AOS Software Mesh R3.0 (Domains) (Upgrade from R2.0) (***)
--------------------------------------------------------------------------------
AOS Software Mesh R4.0 (Mesh Line Switch) (Upgrade from R3.0) (***)
--------------------------------------------------------------------------------
AOS Software R5.0 (***)
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
Hardware Configuration (Eng and Furnish) Hardware Prices
--------------------------------------------------------------------------------
128 OC-48 and 96 OC-192 TCVRs (***)
--------------------------------------------------------------------------------
-48-
--------------------------------------------------------------------------------
HW + SW Configuration (Eng and Furnish) System Prices
--------------------------------------------------------------------------------
128 OC-48 and 96 OC-192 TCVRs (***)
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
PlaNet Software (***)
--------------------------------------------------------------------------------
CIT Software (***)
--------------------------------------------------------------------------------
WMS Software (***)
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
Additional Documentation (***)
--------------------------------------------------------------------------------
Training (see below) (***)
--------------------------------------------------------------------------------
Training: Prices are valid for classes of a minimum of five (5) students and a
maximum of ten (10) students. Courses are offered at Tellium training facility
and includes all training materials.
All Software prices includes first Release released following delivery of
initial release of software delivered with Product (other than ISU's which
remain at no cost) at no additional cost to Qwest.
-49-
SCHEDULE D
----------
Purchase Order Procedures
I. Purchase Orders
Any shipment of Product or Service from Tellium for Qwest must occur only in
accordance with a formal, authorized Qwest Purchase Order
Individuals authorized to sign, issue and place Purchase Orders for Qwest are as
follows:
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***) (***)
(***)
This list may be updated by Qwest upon written notice to Tellium.
II. Quote and Order Process
Qwest Engineering will either request a proposal from Tellium or issue Purchase
Orders based on contracted pricing Schedule A. Tellium will ensure that
proposal pricing is accurate and consistent with the pricing presented in the
Agreement and price lists furnished to Qwest Procurement. Tellium will resolve
any price discrepancies with Qwest Procurement. Tellium will resolve any
equipment discrepancies with Qwest's Engineer(s) prior to Qwest's acceptance of
the proposal, and before the proposal is submitted for ordering. Tellium will
adhere to the pricing guidelines set forth in this Agreement, and will be
responsible for ensuring the accuracy of this pricing on any and all proposals
and/or invoices.
All Qwest Purchase Orders will be accepted by Supplier's transmittal to Qwest of
a sales order acknowledgement. Such acknowledgement shall be sent by email or
facsimile to a person or department designated by Qwest, within (***) of receipt
of a Purchase Order. Supplier may request additional time to respond to the
Qwest Purchase Order, but Qwest is under no obligation to grant such an
extension. If the PO is deemed inaccurate by Tellium for any reason, Tellium
-50-
shall contact the Buyer noted above within (***) of receipt.
III. Delivery and Shipment
Delivery and Shipment shall take place in accordance to Section 8 of the
Agreement.
Once a final shipment of a Purchase Order has been made, Tellium will invoice
Qwest for said material. The invoice will match the Packing Slips in its
entirety in order to accurately be received in the Qwest system for process of
payment. If there is a discrepancy of any of these two (2) documents, Qwest
will notify Tellium within (***) of such discrepancy. Qwest shall have the right
to delay payment until such discrepancy is resolved. Any dispute as to invoiced
amounts shall be governed by Section 9.2 of this Agreement.
When equipment arrives on site it will be inventoried against the packing slip,
and any discrepancies will be brought to the immediate attention of Tellium
Order Management.
IV. Invoicing Procedures
Send all invoices issued to Qwest Communications Corporation to the following
address:
Qwest Communications Corporation
000 00/xx/ Xxxxxx
Xxxxx 0000
Attention: Accounts Payable
Xxxxxx, XX 00000
Send all invoices issued to Qwest N Limited Partnership to the following
address:
Qwest N Limited Partnership
000 00/xx/ Xx.
Xxxxx 0000
Attention: Accounts Payable
Xxxxxx, XX 00000
All invoices must match the Qwest Procurement Department issued Purchase Order
exactly. Each Line Item, Price, Qty., etc. must match exactly before invoicing.
If there are discrepancies, please contact the appropriate Buyer prior to
invoicing. Please wait for verification from the Buyer before sending the
invoice to Accounts Payable.
All invoices must clearly state the Qwest Procurement Department issued Purchase
Order number. This number consists of 12 digits, the format is similar to this:
02-0000070000 (QCC P.O.) or 50-00000700000 (Q.N.LP P.O). Additionally, Qwest
may issue a PO
-51-
from our XX Xxxxxxx system. Again, these orders will reference one of the
authorized individuals as listed above and the format will be as follows: 70000-
000 OP. Qwest Communications does not authorize the use of any other Purchase
Order Numbers. If a Purchase Order Number is received that varies from the
format mentioned above from an individual claiming to be an authorized agent of
Qwest Communications, verify the accuracy of the number by contacting the Buyer.
No shipments should be made based solely on a verbal conversation.
All invoices should state the name and telephone number of the Buyer who
authorized the purchase.
-52-
SCHEDULE E
----------
TRAINING
--------
Tellium provides training to customers covering all of the necessary topics, as
agreed upon, for the installation, operation and maintenance of our equipment
including both hardware and software systems.
Currently, centralized training is offered at our Oceanport, New Jersey
location. Tellium will provide instructors and the necessary instructional
material in our standard format to train Customer personnel, (including
personnel of Customer affiliated companies) in the installation, planning and
practices, operation, maintenance, and trouble shooting / repair of Tellium
products purchased or evaluated by the Customer. These classes will be
conducted at reasonable intervals and at locations as agreed upon by Tellium and
the Customer. At the option of the Customer, Tellium agrees to supply the
Customer with training modules and/or manuals and any necessary assistance to
allow the Customer to conduct a training program of it's own should the Customer
enter into an agreement to purchase said products.
Custom "suit cased" courses will be offered as customer requirements are known.
Suit case classes can only be provided at locations where equipment is available
for "hands on" training.
The following is a list of training courses that are offered:
Course #Title Duration
OXPF Optical Switch Product Family Overview 1 Day
The course provides an overview of the evolution of the
Aurora Optical Switch product line. This course covers
the basic engineering principles that are to be
considered when deploying all OXCs and specific network
design parameters that should be evaluated. The current
schedule for availability of product hardware and
software features will be discussed in detail. This
course is incorporated into OXC 32-1 and OXC 32-2.
OXC 512-1 Aurora Optical Switch
Product Engineering & Applications Course 2 days
This course will provide details on the engineering guidelines of the Aurora
Optical
-53-
Switch. Bay layout and engineering details for all interface connections will be
covered. The functionality of all modules will be reviewed. Discussions of
various applications for the cross-connect are to be addressed and comparisons
made to other possible technology implementations. In addition we will provide
an overview of network architectures that provide protection and restoration
using the Optical Switch.
OXC 512-2 Aurora Optical Switch
Installation, Operation, Software Provisioning and
Maintenance Course 3 days
This course will detail all of the installation
activities and engineering considerations that are to
be addressed for deployment of an Aurora Optical
Switch. The course will detail the installation and
test procedures for turning up the equipment and all
circuit-packs. An overview of system administration and
operations support for different configurations will be
provided. Details of cabling, power requirements, HVAC
and space demands will be covered. All software
features and functions will be reviewed. There will be
a special focus given to the provisioning of and
removal of actual cross-connects, both on a point-to-
point and point-to-multi-point basis.
Course Notes:
1. In order to facilitate the required 50% "hands-on" time required for each
class, courses are typically offered to a class with a minimum of 5 and a
maximum of 10 students.
2. Currently, course material is provided in a text format on paper or soft
copy. Other media such as audio or video may be developed as required.
-54-
SCHEDULE F
----------
(***)
(***)
(***)
(***)
This document presents a (***) for (***) the (***). The Aurora Optical Switch
(AOS) is an optical layer cross-connect system with a capacity of 512 bi-
directional parts operating at the SONET rate of OC-48. The AOS is (***) by
(***) either through the (***) or the (***) running on a (***). The following is
a summary of the (***) in the (***):
. (***).
. (***) for the (***). An (***) with the (***) and (***) as the (***) is
(***).
. (***): Allows (***) to be (***) to (***), where (***).
. (***) is a (***) that uses (***) at the (***) to (***) in the event of a
(***).
. (***): The (***), and (***) of (***) in the (***). A (***) that exists for
a (***) is (***) as an (***) with a (***) or (***).
. (***) deals with the (***), and (***) of (***) and (***) associated with a
(***).
. (***): A (***) that allows (***) of (***).
(***)
. (***) and (***) access (***) and (***).
(***) and (***)
(***) the (***) of the (***).
. (***) to (***) and (***).
. (***) in the (***).
. (***) from the (***).
-55-
. (***) in the (***) and (***).
. (***) and (***) of all (***).
. (***).
. (***) by the (***).
. (***) and (***).
. (***).
. (***).
. (***).
. (***) the (***) of (***).
. (***) and (***).
. (***) the (***) from the (***).
(***)
(***) the (***).
. (***):
. (***)
. (***)
. (***)
. (***):
. (***) with (***)
. (***) and (***)
-56-
. (***) of (***) and (***)
. (***)
. (***) that (***) with (***) cannot (***) that (***) for their (***).
. (***)
. (***) for (***) prior to (***).
. (***) for (***) after (***).
(***)
(***), and (***) via the (***) and the (***).
. (***), such as (***), and (***).
. (***).
. (***), and (***).
. (***).
. (***) of (***).
. (***) and (***).
. (***) and (***).
. (***) and (***).
. (***) and (***).
. (***) of (***) upon (***).
. (***).
-57-
. (***).
. (***) and (***).
(***)
(***) AND (***) AND (***) VIA (***) AND (***) ON THE (***) AND (***).
. (***), and (***) related to (***), and (***).
. (***), and (***) such as (***), and (***).
. (***) in the (***) with a (***).
. (***) in the (***) with a (***).
. (***) in the (***) with a (***).
. (***) by the (***).
. (***) of (***), and (***).
. (***) the (***) on the (***), and (***) are (***) during the (***).
. (***) the (***) and (***) is (***) on (***).
. (***) such as (***) and (***).
. (***) into/from (***).
(***)
-58-
(***) are (***) in this section. The (***) to (***), and (***).
If the (***) is (***) for (***), it must be (***) that the (***) is (***) when a
(***) in the (***) is (***) to the (***). Where in (***), it must be (***) that
a (***) is (***) to the (***) in (***). In (***), a (***) to (***) is (***) the
(***) has (***) from the (***) that (***) the (***).
Following are the (***) for the (***) of this (***):
. (***)
. (***)
. (***) of (***) to (***)
. (***) of (***) to (***)
. (***) of (***) to (***)
. (***) of (***) to (***)
. (***) of (***)
. (***)
. (***)
. (***)
. (***)
(***)
(***) of (***) by (***) and (***).
. (***) the (***) of the (***).
. (***) for (***) and (***).
. (***) and (***) for the (***) and (***).
-59-
(***)
(***) the (***) under various (***) for an (***), such as (***) or (***).
. (***) a (***) between (***) in (***) of the (***) or (***).
. (***) a (***) for (***) or (***).
. (***) a (***) on a (***) on (***).
. (***) a (***) of (***) on a (***) on (***).
-60-
SCHEDULE G
----------
TECHNICAL SUPPORT SERVICES
--------------------------
Ongoing technical support and emergency problem resolution will be available on
a (***) basis. Tellium supplies technical assistance support services from its
Oceanport, NJ facility.
With regards to response times, Tellium recognizes that each customer has their
own goals and objectives as well as methods of operation. Due to this, Tellium
has adopted the policy that specific response times for technical on-site
assistance will be defined to meet each individual customer's needs. Tellium
represents and warrants that Tellium's 24 hour technical support telephone
service will provides customers communications with Tellium technical support
personnel within (***) of the initial call from the customer to the help line at
1-888-TELLIUM (0-000-000-0000).
------------------------------------------------------------------------
Level of Outage Technical Support
------------------------------------------------------------------------
Out-of-Service Tellium provides on-site technical
(Failure causes service support within (***); Tellium (***).
outage)
------------------------------------------------------------------------
Service Impaired (***) technical support provided
(System is operational, but within (***).
Quality of service is
compromised; e.g.
performance monitoring
software is malfunctioning)
------------------------------------------------------------------------
Non-service affecting (***) technical support is scheduled
by (***).
------------------------------------------------------------------------
-61-
SCHEDULE H
----------
TELLIUM REPAIR AND RETURN POLICY
--------------------------------
The Aurora Optical Switches are equipped with field replaceable modules.
Tellium's routine or non-emergency repair & returns policy is to repair or
replace a defective module (***) from receipt and Tellium represents that
it will repair or replace Products within such time period. If products
returned to Tellium are determined to be beyond repair, Tellium shall so
notify Qwest of the need to replace such product.
Tellium provides a standard emergency repair and return service within
(***), or, whenever possible, ships replacement parts within (***). Tellium
can maintain a (***) for (***) (see Spares plan) to (***) ((***) if
distance permits), once negotiated with Qwest.
The Tellium routine Repair and Return service is managed via a return
authorization process.
This process is as follows:
1 When a module is suspected as being defective (hardware or
software), the customer calls Tellium's Customer Service number.
2 If it is determined that the module is indeed defective, the
customer is issued a Return Authorization Number for tracking and
shipping to Tellium. Customer is responsible for shipping
expenses to Tellium.
3 The defective module will then be repaired or replaced and
returned to the customer. Tellium is responsible for shipping
expenses back to the customer.
4 Repair of module(s) still under warranty is (***) unless it is
determined that the defect was caused by (***).
5 Repair of module(s) not covered under warranty will be charged at
the rate of (***). If repaired cost is greater than (***) of
individual module cost, module will be replaced rather than
repaired. Tellium to notify QWEST prior to replacement of
modules. Qwest will be invoiced at the then agreed upon charge.
-62-
SCHEDULE I
----------
Software Maintenance Agreement
------------------------------
MAINTENANCE AND SUPPORT.
A. Supplier shall provide maintenance and support through the (***) after the
date of delivery of the Software (***) in accordance with Section 13.6(c) of the
Purchase Agreement. Thereafter, if Qwest elects to receive software support,
Qwest shall pay an annual fee of (***) ((***)) as a Maintenance Fee.
B. Supplier shall provide (***), (***) support for answering questions
regarding operation of the Software and for reporting problems with the
Software.
C. Supplier shall provide (***) for any (***) or comparable (***) or (***) in
the Software and regular preventive maintenance. (***) that Response time for
service affecting problems will be within (***).
D. Supplier shall provide (***), (***), (***), (***), (***) of the same type
and quality that Supplier provides to its customers who are covered by a fixed
effort/budgeted maintenance agreement. Without modification of the terms and
conditions of the Agreement, additional new features or customer specific
features shall be subject to charges negotiated between Qwest and Supplier from
time to time.
E. Supplier shall provide (***) technical support (***). Qwest agrees to pay
for such (***) at the rates indicated in Schedule C, Products and Pricing of the
Purchase Agreement.
F. Maintenance and support shall not include the following: (a) (***); (b)
(***); (c) repair of damage resulting from (***), (***), (***), or (***) other
than (***), unless any such acts are the result of (***) or (***) or (***); (d)
(***), or (***) or (***), (***), or (***); (e) such service that is (***) to
render because of (***) in the (***) or (***), (***), (***), or (***) provided
by someone other than an (***) of (***), (***) of (***); (h) (***) and (***);
(i) (***) or (***) necessitated by use of (***) or (***).
G. Supplier assumes no responsibility if anyone other than an authorized
Supplier representative modifies or otherwise tampers with the hardware,
Software, or operating system except in the manner set forth in the
Documentation or otherwise at Supplier's direction.
H. Charges for any maintenance services or other work performed by Supplier
stemming from any of the above exclusions will be separately invoiced to Qwest
at
-63-
Supplier's time and expense rates in effect at the time such services are
rendered. Prior written notice must be provided to and approved by Qwest, if
charges for maintenance services or other work
-64-
SCHEDULE J
(***)
(***), (***) to (***) on the Aurora Optical Switch (***) for (***). The Aurora
Optical Switch is designed to provide automated service delivery and restoration
of optical services in primarily regional and national networks. Its initial
capacity delivers 1.28 terabytes of switching bandwidth or 512 optical channels
at 2.5 Gbps. Each of the interfaces supports either SONET or SDH signals under
software control. The Aurora Optical Switch operates at optical signal speeds
up to 10 Gbps and is designed for service providers that anticipate high rates
of growth in their network locations. The Aurora Optical Switch is modular and
designed to grow to many times its initial capacity while the network and
product remain in service.
(***), (***) the (***). The Aurora Full Spectrum is an all optical switch
currently in development. The Aurora Full Spectrum is designed to combine a pure
optical switch matrix capable of switching at OC-768 and faster signal speeds.
It supports the mesh networking while switching optical traffic at more than 40
Gbps. StarNet - Service Delivery and Restoration Software. StarNet is the
operating system software for the optical switches. The StarNet software
provides the communication between switches, routes optical signals around
network failures and performs optical service provisioning for the mesh network.
StarNet mesh algorithms allow many working paths to share a single protection
path, saving equipment costs in traditional ring networks. Wavelength Management
System - Element Management Software. The Wavelength Management System provides
fault location, network configuration, performance monitoring and analysis, and
network security. In addition, this system provides the capability to operate,
administer, maintain and provision the entire optical switching network, not
just individual network elements.
When used in combination with DWDM transport systems, Aurora switches
enable service providers to automate the delivery of optical services, reduce
their costs by enabling optical mesh networking, restore optical services in the
event of network failures and redirect traffic around network bottlenecks.
Aurora switches also provide the ability to connect the new generation of high-
speed IP routers and switches directly to the optical network without requiring
additional expensive SONET/SDH equipment. The diagram below describes the
typical use and network architecture Aurora products support.
-65-
